(3-2018) Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
CAM #4844-6202-6590 v1
CITY OF CAMARILLO
PUBLIC WORKS CONTRACT
(Informal Bid Work)
This contract (“Contract”) is effective as of April 10 , 2024, and is between the C ITY OF CAMARILLO, a California general law city and municipal corporation (“ City”), a nd Econolite Systems, Inc. a California Corporation (“Contractor”), collectively referred to as the “Parties.” Section 1. Recitals. This Contract is entered into with respect to the following facts:
1.1 City received a proposal for the work involved in Project No. TM -2023-3 CAMARILLO VIDEO DETECTION PROJECT (“Project”), which is more fully described in the Contract Documents defined below.
1.2 Contractor represents it is qualified to perform all of the work required to complete the Project.
1.3 Contractor agrees to perform all such work in the time and manner set forth in the Contract Documents.
Section 2. Contract Documents . This Contract consists of the following documents (“Contract Documents”), all of which are made a part of this Contract:
2.1 Proposal, as accepted, including the List of Subcontractors (if any)
2.2 Notice to Proceed
2.3 This Contract
2.4 Verification of California Contractor’s License
2.5 Certificate of DIR Contractor Registration
2.6 Certificate Regarding Workers’ Compensation
2.7 Security for payment (labor and materials)
2.8 Security for performance
2.9 Certificate(s) of Insurance
2.10 Prevailing Wage Scales
2.11 Addenda No. #1 dated 02/20/2024
2.12 Other documents (list here)
Exhibit A – Special Provisions and Scope of Work
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
(3-2018) Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
CAM #4844-6202-6590 v1
Exhibit B - Compensation
Exhibit C – Insurance
Section 3. The Work.
3.1 The work (“ Work”) to be performed by Contractor is described in the Contract Documents set forth in Exhibit A (“Scope of Work”), which is made a part of this Contract.
3.2 In completing the Work, Contractor must employ, at a minimum, the applicable generally accepted professional standards of its industry in existence at the time of performance as utilized by persons engaging in similar work.
3.3 Except as specifically provided in the Contract Documents, Contractor must furnish, at its sole expense, all of the labor, materials, tools, equipment, services and transportation necessary to perform all of the Work.
3.4 Contractor must perform all of the Work in strict accordance with the Contract Documents.
Section 4. Time to Perform the Work.
4.1 Time is of the essence with respect to Contractor’s Work. Contractor agrees to diligently pursue performance of the Work within the time specified by the Contract Documents.
4.2 Contractor will be excused from any delay in performance or failure to perform due to causes beyond the control of Contractor. Such causes include, but are not limited to, acts of God, acts of terrorism, acts of federal, state or local governments, acts o f City, court orders, fires, floods, epidemics, strikes, embargoes, and unusually severe weather.
4.3 If Contractor is delayed by any cause beyond Contractor’s control, City may, but is not required to, grant a time extension for the completion of the Work. If delay occurs, Contractor must notify City in writing within 48 hours of the cause and the extent of the delay and how such delay interferes with Contractor’s performance of the Work.
Section 5. Compensation and Payment.
5.1 Subject to any limitations provided in the Contract Documents, City agrees to pay Contractor as full consideration for the faithful performance of all of the Work the compensation set forth in Exhibit B (“Compensation”), which is made a part of this Contract.
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
(3-2018) Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
CAM #4844-6202-6590 v1
5.2 Contractor must furnish City with a Pay Estimate for the Work performed in accordance with the Contract Documents. Contractor may not submit a Pay Estimate more often than once every 30 days.
5.3 City will review each Pay Estimate and determine whether the Work performed is in accordance with the Contract Documents. The D irector of Public Works (“Director”) may require Contractor to provide a release of all undisputed Contract amounts contained in the Pay Estimate.
5.4 If City disputes any item on a Pay Estimate, City will give Contractor notice stating the reasons for the dispute. The Parties will meet and confer in good faith to attempt to resolve the dispute.
5.5 Except as to any charges for the Work performed that City disputes and the City’s standard five-percent retention of the approved progress payment, City will cause Contractor to be paid within 30 days of the date of the invoice or the date that Contractor furnishes City with a release of all undisputed Contract amounts, whichever occurs later. Federally funded projects will not have a five -percent retention.
5.6 In the event there is any claim specifically excluded by Contractor from the operation of any release, City may retain an amount not to exceed the amount of the excluded claim.
Section 6. Labor Code and Prevailing Wage Requirements.
6.1 Contractor agrees to comply with the requirements of California Labor Code sections 1810 through 1815. E ight hours of labor constitutes a legal day’s work per Labor Code s ection 1810. Contractor will forfeit the statutory penalty to City for each worker employed in the execution of this Contract by Contractor or any subcontractor for each calendar day during which such worker is required or permitted to work more than eight hours in any one calendar day and 40 hours in any one calendar week in violation of the provisions of Labor Code sections 1810 through 1815.
6.2 Copies of the determination of the Director of the Department of Industrial Relations of the prevailing rate of per diem wages for each craft, classification or type of worker needed to execute this Contract are available for download from the State website: http://www.dir.ca.gov/OPRL/dprewagedetermination.htm.
6.3 Contractor must post at the work site, or if there is no regular work site then at its principal office, for the duration of the Contract, a copy of the determination by the Director of the Department of Industrial Relations of the specified prevailing rate of per diem wages. (Labor Code § 1773.2.) When applicable, copies of the prevailing rate of per diem wages will be on file at City ’s Department of Public Works and available to Contractor and any other interested party upon request.
6.4 Contractor, and any subcontractor engaged by Contractor, may pay not less than the specified prevailing rate of per diem wages to all workers employed in the Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
(3-2018) Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
CAM #4844-6202-6590 v1
execution of the contract. (Labor Code § 1774.) Contractor is responsible for compliance with Labor Code section 1776 relative to the retention and inspection of payroll records.
6.5 Contractor must comply with all provisions of Labor Code section 1775. Under Section 1775, Contractor will forfeit the statutory penalty to City for each worker employed in the execution of the Contract by Contractor or any subcontractor for each calendar day, or portion thereof, in which the worker is paid less than the prevailing rates. Contractor may also be liable to pay the difference between the prevailing wage rates and the amount paid to each worker for each calendar day, or portion thereof, for w hich each worker was paid less than the prevailing wage rate.
6.6 Nothing in this Contract prevents Contractor or any subcontractor from employing properly registered apprentices in the execution of the Contract. Contractor is responsible for compliance with Labor Code section 1777.5 for all apprenticeable occupations. This statute requires that contractors and subcontractors must submit contract award information to the applicable joint apprenticeship committee, must employ apprentices in apprenticeable occupations in a ratio of not less than one hour of apprentice’s work for every five hours of labor performed by a journeyman (unless an exception is granted under § 1777.5), must contribute to the fund or funds in each craft or trade or a like amount to the California Apprenticeship Council, and that contractors and subcontractors must not discriminate among otherwise qualified employees as apprentices solely on the ground of sex, race, religion, creed, national origin, ancestry or color. Only apprentices defined in Labor Code section 3077, who are in training under apprenticeship standards and who have written apprentice contracts, may be employed on public works in apprenticeable occupations.
6.7 Contractor has reviewed and agrees to comply with any applicable provisions for any public work subject to Department of Industrial Relations (DIR) Monitoring and Enforcement of prevailing wages, including the registration requirements of Labor Code Section 1771.1(a). City hereby notifies Contractor that Contractor is responsible for submitting certified payroll records directly to the State Compliance Monitoring Unit (CMU). For further information concerning compliance monitoring please visit the website location at: http://www.dir.ca.gov/dlse/cmu/cmu.html.
6.8 Contractor must comply with Labor Code s ection 1771.1(a), which provides that Contractor may award any contracts and subcontracts for work that qualifies as a “public work” only to subcontractors which are at that time registered and qualified to perform public work pursuant to Labor Code s ection 1725.5. Contractor must obtain proof of such registration from all such subcontractors.”
6.9 If federal funds are used to pay for the Work, Contractor and any subcontractor agree to comply, as applicable, with the labor and reporting requirements of the Davis-Bacon Act (40 USC § 276a-7), the Copeland Act (40 USC § 276c and 18 USC §874), and the Contract Work Hours and Safety Standards Act (40 USC § 327 and following).
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
(3-2018) Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
CAM #4844-6202-6590 v1
Section 7. Non-Discrimination. Contractor, its officers, agents, employees, and subcontractors may not discriminate in the employment of persons to perform the Work in violation of any federal or state law prohibiting discrimination in employment, including based on the race, religious creed, color, national origin, ancestry, physical disability, mental disability, medical condition, genetic information, marital status, sex, gender, gender identity, gender expression, age, sexual orientation, of any person, except as provided under California Government Code section 12940. Contractor is responsible for compliance with this section.
Section 8. G
eneral Legal Compliance.
8.1 In performing the Work, Contractor must comply with all applicable statutes, laws and regulations, including, but not limited to, OSHA requirements and the Camarillo Municipal Code.
8.2 Contractor must, at Contractor’s sole expense, obtain all necessary permits and licenses required for the Work, and give all necessary notices and pay all fees and taxes required by law, including, without limitation, any business license tax imposed by City.
8.3 Contractor must maintain a valid California Contractor’s License throughout the term of this Contract.
Section 9. Clayton and Cartwright Act Assignments. In entering into this Contract or a contract with a subcontractor to supply goods, services, or materials pursuant to this Contract for the Project, Contractor and any subcontractor will be deemed to have offered and agreed to assign to City all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Sec. 15) or under the Cartwright Act (Chapter 2, commencing with Section 16700 of Part 2 of Division 7 of the California Business and Professions Code), arising from purchases of goods, services, or materials for the Project. This assignment will be deemed made and will become effective at the time City tenders final payment to Contractor, without further acknowledgement by the Parties.
Section 10. I
ndependent Contractor. Contractor is and will at all times remain as to City a wholly independent contractor. Neither City nor any of its officers, employees, or agents will have control over the conduct of Contractor or any of Contractor’s officers, employees, agents or subcontractors, except as expressly set forth in the Contract Documents. Contractor may not at any time or in any manner represent that it or any of its officers, employees, agents, or subcontractors are in any manner officers, employees, agents or subcontractors of City.
Section 11. I ndemnification.
11.1 Contractor agrees to the fullest extent permitted by law to (1) immediately defend and (2) indemnify City from and against, any and all claims and liabilities, regardless of the nature or type, that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of Contractor, or its officers, employees, agents, or subcontractors com mitted in performing any Work under Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
(3-2018) Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
CAM #4844-6202-6590 v1
this Contract or the failure to comply with any of the obligations of this Contract (collectively, “Claims”). The Claims subject to Contractor’s duties to defend and indemnify include, without limitation, all claims, actions, causes of action, proceedings, suits, losses, damages, penalties, fines, judgments, liens, levies, and associated investigation and administrative expenses. Such Claims also include defense costs, including reasonable attorneys’ fees and disbursements, expert fees, court costs, and costs of alternative dispute resolution.
11.2 Contractor’s duty to defend is a separate and distinct obligation from Contractor’s duty to indemnify. Contractor is obligated to defend City in all legal, equitable, administrative, or special proceedings, with counsel approved by City, immediately upon tender to Contractor of the Claim in any form or at any stage of an action or proceeding, whether or not liability is established. An allegation or determination that persons other than Contractor are responsible for the Claim does not r elieve Contractor from its separate and distinct obligation to defend under this section.
The obligation to defend extends through final judgment, including exhaustion of any appeals. The defense obligation includes an obligation to provide independent defense counsel if Contractor asserts that liability is caused in whole or in part by the negligence or willful misconduct of any City indemnified party. If it is finally adjudicated that liability was caused by the comparative active negligence or willful misconduct of any City indemnified party, then Contractor may submit a claim to City for reimbursement of reasonable attorneys’ fees and defense costs in proportion to the established comparative liability of the City indemnified party.
11.3 Contractor agrees that its defense and indemnification obligation under this section, includes the reasonable costs of attorneys’ fees incurred by the City Attorney’s office to monitor and consult with Contractor regarding the defense of any Claims, including providing direction with regard to strategy, preparation of pleadings, settlement discussions, and attendance at court hearings, mediations, or other litigation related appearances. City will use its best efforts to avoid duplicative attorney work or appearances in order to keep defense costs to a reasonable minimum.
11.4 Contractor agrees that settlement of any Claim will require the consent of City .
City agrees that its consent will not be unreasonably withheld provided that Contractor is financially able (based on demonstrated assets) to fulfill its obligation to indemnify City for the costs of any such settlement as required under this Contract.
11.5 Contractor’s obligation to indemnify City applies unless it is finally adjudicated that the liability was caused by the sole active negligence or sole willful misconduct of a City indemnified party. If a Claim is finally adjudicated and a determination made that liability was caused by the sole active negligence or sole willful misconduct of a City indemnified party, then Contractor’s indemnification obligation will be reduced in proportion to the established comparative liability.
11.6 For the purposes of this section, “City” includes City’s officers, officials, employees and agents.
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
(3-2018) Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
CAM #4844-6202-6590 v1
11.7 The provisions of this section will survive the expiration or earlier termination of this Agreement.
Section 12. Insurance. Contractor agrees to have and maintain in full force and effect during the term of this Contract the insurance coverages listed in Exhibit C (“Insurance”), which is made a part of this Contract.
Section 13. Notice.
13.1 All written notices required or permitted to be given under this Contract will be deemed made when received by the other Party at its respective address as follows:
To City: C ity of Camarillo
601 Carmen Drive
Camarillo, California 93010
Attention: Jason Samonte
(Tel.) 805-383-5650
(Fax) 805-388-5318
(Email) [email protected]
To Contractor: Econolite Systems, Inc
1250 N. Tustin Avenue
Anaheim, CA 92807
Attention: Christopher Flores
(Tel.) 714-575-5619
(email) [email protected]
13.2 Notice will be deemed effective on the date personally delivered or transmitted by facsimile or email. If the notice is mailed, notice will be deemed given three days after deposit of the same in the custody of the United States Postal Service, postage prepaid, for first class delivery, or upon delivery if using a major courier service with tracking capabilities.
13.3 Any Party may change its notice information by giving notice to the other Party in compliance with this section.
Section 14. City Rights of Termination and to Complete the Work.
14.1 The occurrence of any of the following is a default by Contractor under this Contract:
14.1.1 Contractor refuses or fails to prosecute the Work or any part thereof with such diligence as will insure its completion within the time specified or any permitted extension.
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
(3-2018) Specification No. TM-2023-3
CONTRACT
CC Agr eement 2024-14
CAM #4844-6202-6590 v1
14.1.2 Contractor fails to complete the Work on time.
14.1.3 Contractor is adjudged bankrupt, or makes a general assignment for the benefit of creditors, or a receiver is appointed on account of Contractor’s insolvency.
14.1.4 Contractor fails to supply enough properly skilled workers or proper materials to complete the Work in the time specified.
14.1.5 Contractor fails to make prompt payment to any subcontractor or for material or labor.
14.1.6 Contractor fails to abide by any applicable laws, ordinances or instructions of City in performing the Work.
14.1.7 Contractor breaches or fails to perform any obligation or duty under the Contract.
14.2 Upon the occurrence of a default by Contractor, City will serve a written notice of default on Contractor specifying the nature of the default and the steps needed to correct the default. Unless Contractor cures the default within 10 days after the service of such notice, or satisfactory arrangements accept able to City for the correction or elimination of such default are made, as determined by City, City may thereafter terminate this Contract by serving written notice on Contractor. In such case, Contractor will not be entitled to receive any further payment, except for Work actually completed prior to such termination in accordance with the provisions of the Contract Documents.
Section 15. P
roject Documents . All data, drawings, maps, models, notes, photographs, reports, studies and other documents (collectively, “ Project Documents”) prepared, developed or discovered by Contractor in the course of performing any of the Work under this Contract will become the sole property of City . Upon the expiration or termination of this Contract, Contractor must turn over all original Project Documents to City in its possession, but may retain copies of any of the Project Documents it may desire.
Section 16. Gener
al Provisions.
16.1 Authority to Execute. Each Party represents and warrants that all necessary action has been taken by such Party to authorize the undersigned to execute this Contract and to bind it to the performance of its obligations.
16.2 Assignment. Contractor may not assign this Contract without the prior written consent of City, which consent may be withheld in City’s sole discretion since the experience and qualifications of Contractor were material considerations for this Contract.
16.3 Binding Effect. This Agreement is binding upon the heirs, executors, administrators, successors and permitted assigns of the Parties.
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
(3-2018) Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
CAM #4844-6202-6590 v1
16.4 Integrated Contract. This Contract, including the Contract Documents, is the entire, complete, final and exclusive expression of the Parties with respect to the Work to be performed under this Contract and supersedes all other agreements or understandings, whether oral or written, between Contractor and City prior to the execution of this Contract.
16.5 Modification of Contract. No amendment to or modification of this Contract will be valid unless made in writing and approved by Contractor and by the City Council or City Manager, as applicable. The Parties agree that this requirement for written modifications cannot be waived and that any attempted waiver will be void.
16.6 Electronic Signatures; Counterparts. This Agreement and any amendment will be considered executed when the signature page of a party is delivered by electronic transmission. Such electronic signatures will have the same effect as an original signature. This Agreement may be executed in multiple counterparts.
16.7 Waiver. Waiver by any Party of any term, condition, or covenant of this Contract will not constitute a waiver of any other term, condition, or covenant. Waiver by any Party of any breach of the provisions of this Contract will not constitute a waiver of any other provision, or a waiver of any subsequent breach or violation of any provision of this Contract. Acceptance by City of any Work performed by Contractor will not constitute a waiver of any of the provisions of this Contract.
16.8 Interpretation. This Contract will be interpreted, construed and governed according to the laws of the State of California. Each party has had the opportunity to review this Contract with legal counsel. The Contract will be construed simply, as a whole, and in accordance with its fair meaning. It will not be interpreted strictly for or against either party.
16.9 Severability. If any term, condition or covenant of this Contract is declared or determined by any court of competent jurisdiction to be invalid, void or unenforceable, the remaining provisions of this Contract will not be affected and the Contract will be read and construed without the invalid, void or unenforceable provision.
16.10 Venue. In the event of litigation between the parties, venue in state trial courts will be in the County of Ventura. In the event of litigation in a U.S. District Court, venue will be in the Central District of California, in Los Angeles. [Signatures on the following page.]
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
(3-2018) Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
CAM #4844-6202-6590 v1
The Parties have caused this Contract to be executed by their undersigned authorized agents as follows:
CITY OF CAMARILLO
Greg Ramirez, City Manager
ATTEST:
Kristy Buxkemper, City Clerk
ECONOLITE SYSTEMS, INC., a California Corporation
Christopher Flores, Regional Vice President
Alice Cook, Secretary
Camarillo Business Tax Certificate No. 038013 / Expiration Date 05/31/2024
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
Specification No. TM-2023-3
A-1
CONTRACT
EXHIBIT A
SPECIAL PROVISIONS & SCOPE OF WORK
FOR
TM-2023-3
CAMARILLO VIDEO DETECTION PROJECT
1. DESCRIPTION
The work to be performed consists of Contractor furnishing the entirety of the Video Detection Systems (VDS), materials, equipment, tools, labor, and incidentals necessary for the proposed project, complete and in place.
The work to be performed includes installation of the Econolite Vision VDS or Iteris Apex VDS at the intersections listed below.
The Contractor must provide all new Video Detection Systems, necessary equipment, and cabling.
The Contractor must provide a Certificate of Compliance and a Five-Year Warranty for the Video Detection Systems.
All work associated with this project must conform to the requirements of the State of California Department of Transportation Standard Plans, 2015 Edition, and Standa rd Specifications, 2015 Edition, City of Camarillo Standards , these Special Provisions and Scope of Work as EXHIBIT A.
List of Intersections for the installation of the Video Detection Systems
1. Ventura Boulevard. and Las Posas Road
2. Central Avenue and Del Norte Road
2. BASIS OF SPECIFICATIONS
Unless otherwise noted in these Special Provisions, the basis of specifications for this project shall be the City of Camarillo EXHIBIT A.
Contractor is not allowed to park any vehicles or equipment at the City Corporation Yard.
It will be the Contractor’s responsibility to dispose of all used safety light fixtures.
The Contractor must always be responsible for maintaining the use of sidewalks and keeping the work area clear of debris.
Traffic Signals may be placed on flash mode during the installation work.
3. WORK HOURS
Work shall be done only on weekdays, Monday through Friday, excluding holidays, between 8:00 a.m. and 3:30 p.m. No contractor activity shall encroach into a moving lane CC AGREEMENT 2024-14
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
Specification No. TM-2023-3
A-3
CONTRACT
d. City will execute Contract once payment/performance bonds are provided. e. Contractor submits Typical Traffic Control Plans.
f. Contractor obtains a no fee encroachment permit.
g. Contractor submits a work schedule for City approval. h. City issues a Notice to Proceed and start of workdays period begins.
6. JOBSITE CONDITIONS
It will be Contractor’s responsibility to examine the jobsite where the work is to be performed. If any conditions are noted that mig ht affect the execution of the job, those conditions must be brought to the attention of the City Transportation Engineer prior to commencing the work.
7. PROTECTION OF PROPERTY AND IMPROVEMENTS
Contractor shall assume sole and complete responsibility for protection of public and private property in the vicinity of the jobsite. Contractor, at Contractor’s expense, shall repair or replace to original condition all existing improvements within or i n the vicinity of the jobsite which are damaged as a result of Contractor’s operations.
8. TRAFFIC CONTROL
Typical Traffic control plan for any lane closure includes all labor, tools, equipment, transportation and incidentals necessary to maintain and control all vehicular and pedestrian traffic through the construction site.
One traffic control plan must be typical for a right lane closure on a multilane arterial roadway with a bike-lane. One traffic control plan must be typical for a left turn lane closure on a multilane arterial roadway.
All such work must conform to the CA MUTCD Latest Edition.
All work area traffic control devices, materials and equipment must be in like new condition, as determined by the City Transportation Engineer.
The overall work -site traffic control, warning, and guidance effort shall be continuously monitored by Contractor for its adequacy in detouring traffic around or circulating traffic through the work area. Any deficiencies by Contractor in such monitoring, or correcting inadequate worksite signing, shall be considered just cause for the City Transportation Engineer or his representative to suspend the work.
The compensation for furnishing, placing, maintaining and removing traffic cones, telescoping tree flags, advanced warning signs , flagmen and other safety devices, as required for public safety or as directed by the City Transportation Engineer shall be included in the contract lump sum unit price in the contract Bid Proposal and no additional compensation will be allowed therefore.
9. NOISE ABATEMENT
A maximum noise level limit of eighty-five (85) decibels at a distance of fifty (50) feet shall apply to all construction equipment on or related to the project whether owned by Contractor or not. The use of excessively loud warning signals shall be avoided except in those cases required for the protection of personnel. The use of generators or other CC AGREEMENT 2024-14
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
Specification No. TM-2023-3
A-5
CONTRACT
will be liable for costs of such corrective work. Such action by City will not relieve Contractor of the warranties and guaranties provided in this Section or elsewhere in the Contract.
CC AGREEMENT 2024-14
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
Specification No. TM-2023-3
A-6
CONTRACT
EXHIBIT A
SCOPE OF WORK
1. All work associated with the furnish ment and installation of the Video Detection Systems shall conform to the requirements of the State of California Department of Transportation Standard Plans, 2015 Edi tion, and Standard Specification s, 2015 Edition, City of Camarillo Standards, and the Scope of Work as Exhibit A.
2. Work shall be done only on weekdays, Monday thru Friday, 8:00 am to 3:30 pm, excluding holidays. No contractor activity shall encroach into a moving lane of traffic before 8:30 am or after 3:30 pm, unless otherwise approved by the City Transportation Engineer.
3. Contractor must possess a current California Class C-10 license. Field electricians shall be California certified electricians per the Division of Apprenticeship Standards. A state certified electrician shall be present during any electrical work.
4. Contractor must provide a typical traffic control closure plan in conformance with the CA MUTCD latest edition, for any right or left lane closures associated with this work.
5. Contractor must provide a Certificate of Compliance and Five-Year Warranty for all Video Detection Systems.
6. Contractor is not allowed to park any vehicles or equipment at the City Corporation Yard.
7. Contractor must always be responsible for maintaining the use of sidewalks and keeping the work area clear of debris.
8. Contractor has discretion to utilize the Econolite Vision VDS or Iteris Apex VDS at these locations. Whichever system is chosen, they should include all materials and labor to provide a workin g vehicle detection so lution. Four (4) cameras for each location will be required along with a 15 pin to 25 pin SDLC cable for utilizing the SP 3 functionality of the city’s 2070 Omni controllers. VDS Manufacturer Support is required on day of turn on.
9. List of Intersections for the installation of the Video Detection Systems.
1. Ventura Boulevard and Las Posas Road.
2. Central Avenue and Del Norte Road
CC AGREEMENT 2024-14
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
A-7
Specification No. TM-2023-3
CC AGREEMENT 2024-14
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
A-8
Specification No. TM-2023-3
CC AGREEMENT 2024-14
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
Specification No. TM-2023-3
CO NTRACT
CC Agreement 2024-14
CAM #4844-6202-6590 v1 B-1
EXHIBIT B
COMPENSATION
The total compensation under this Contract will not exceed:
AL
TERNATE 1
If a Lump Sum Bid: “The sum of $ .”
ALTERNATE 2
If a Unit Price Bid: “The total unit prices set forth in the bid and the actual measured quantities utilized for the Project as determined by the Director.” ALTERNATE 3
If both Lump Sum and Unit Price Bid: “The sum of $57,802.54, and the amount due based upon the unit prices set forth in the bid and the actual measured quantities utilized for the Project as determined by the Director.” Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
C-1
CAM #4844-6202-6590 v1
EXHIBIT C
INSURANCE
1. General Requirements. Contractor must procure and maintain in full force and effect during the term of this Contract the following types of insurance with coverage limits complying, at a minimum, with the limits set forth below:
Type of Insurance Limits (combined single)
Commercial General Liability $2,000,000 / $4,000,000 Aggregate Business Automobile Liability $2,000,000
Workers’ Compensation Statutory Requirements
2. Commercial General Liability Insurance. This policy must meet or exceed the requirements of
Insurance Services Office (ISO) CGL Form No. CG 00 01. The amount of insurance set forth above will be a combined single limit per occurrence for bodily injury, personal injury, and property damage for the policy coverage. The insurance must be on an “occurrence” not a “claims -made” basis. Defense costs must be paid in addition to limits. There must be no cross-liability exclusion for claims or suits by one insured against another.
Liability policies must be endorsed to name City,
its officials, employees and agents as
“additional insureds” under the insurance coverage.
The policy must state that such insurance will be deemed “primary” such that any other i
nsurance that may be carried by City will be deemed “excess” to that of Contractor. This endorsement must be reflected on ISO Form No. CG 20 01, or equivalent form as determined by City.
C
overage must be applicable to City for injury to employees of Contractor, subcontractors, agents or others performing any part of the Work required under this Contract. Each policy must be endorsed to provide a separate limit applicable to this Project.
The Commercial General Liability policy must not contain any endorsements limiting coverage beyond the basic policy coverage for any of the following:
1. Explosion, collapse or underground hazard (XCU);
2. Products and completed operation;
3. Pollution liability; or
4. Contractual liability.
3. Business Auto Coverage. This policy must be on ISO Business Auto Coverage Form CA 00 01 including symbol 1 (Any Auto) and Endorsement CA 0025, or equivalent forms approved in writing by City . If Contractor neither leases nor owns vehicles, this requirement may be satisfied by a non- owned auto endorsement to the general liability policy described above. If Contractor or Contractor’s employees will use personal autos Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
C-2
CAM #4844-6202-6590 v1
in any way on this Project, Contractor must provide evidence of personal auto liability coverage for each such person.
4. Workers Compensation. Contractor must have a State of California approved policy form providing the statutory benefits required by law with employer’s liability limits, or Contractor must provide evidence of an approved self-insurance program.
5. Other Insurance; Revisions to Insurance. Contractor may be required to obtain such other insurance coverage as may be required by applicable law or by City. City reserves the right at any time during the term of the Contract to change the amounts and types of insurance required by giving Contractor 60 days advance written notice of such change.
If such change results in substantial additional cost to Contractor, City and Contractor may renegotiate Contractor’s compensation.
6. Acceptable Insurers. All required insurance policies must be issued by an insurance company currently authorized by the California Insurance Commissioner to transact the business of insurance in the State of California, with an assigned policyholders’ Rating of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best’s Key Rating Guide, unless otherwise approved by the City ’s Risk Manager.
7. Excess or Umbrella Liability Insurance (Over Primary). If an excess or umbrella liability policy is used to meet limit requirements, the insurance must provide coverage at least as broad as specified for the underlying coverages. Any such coverage provided under an excess or umbrella liability policy must include a “drop-down provision” providing primary coverage above a maximum $25,000 self-insured retention for liability not covered by primary but covered by the umbrella. Coverage must be provided on a “pay-on-behalf” basis, with defense costs payable in addition to policy limits. There may be no cross - liability exclusion precluding coverage for claims or suits by one insured against another.
Coverage must be applicable to City for injury to employees of Contractor, its subcontractors or others performing work to satisfy Contractor’s obligations under this Contract. The scope of coverage provided is subject to approval of City following receipt of proof of insurance as required herein.
8. Certificates of Insurance and Endorsements. Prior to commencing any Work under this Contract, Contractor must file with the City Certificates of Insurance and Endorsements evidencing the existence of all insurance required by this Contract, along with such other evidence of insurance or copies of policies as may reasonably be required by City. Such Certificates of Insurance and Endorsements must be in a form approved by City’s Attorney. Contractor must maintain current certificates and endorsements on file with City during the term of this Contract reflecting the existence of all required insurance.
Each of the certificates must expressly provide that no material change in the policy, or termination thereof, will be effective except upon 30 days’ prior written notice to City.
9. Failure to Maintain Required Insurance. If Contractor, for any reason, fails to have in place at all times during the term of this Contract all of the required insurance coverage, City may, in addition to any other available remedies, (a) obtain such coverage at Contractor’s expense and deduct the cost from the sums due Contractor, (b) make a claim against the Contractor’s surety, or (c) terminate the Contract.
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
C-3
CAM #4844-6202-6590 v1
10. Effect of Coverage. The existence of the required insurance coverage under this Contract will not be deemed to satisfy or limit Contractor’s indemnity obligations under this Contract.
11. Higher Limits of Insurance. If Contractor maintains higher limits of insurance than the required amounts shown in Section 1 above, then such amounts will be the minimum required under this Agreement.
.
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
CAM #4844-6202-6590 v1
CERTIFICATE OF CALIFORNIA
CONTRACTOR’S LICENSE
I certify, under penalty of perjury, that Contractor has a valid California Contractor’s license issued pursuant to Business and Professions Code section 7000 and following:
California Contractor’s License:
969067 C- 10 Electrical 01/31/2026
License Number Class Expiration Date
Name & Title (print or type)
Date Signature
(Public Contract Code § 6100)
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
Christopher Flores, Regional Vice-President
03 / 25 / 2024
Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
CAM #4844-6202-6590 v1
CERTIFICATE REGARDING DEPARTMENT OF INDUSTRIAL
RELATIONS CONTRACTOR REGISTRATION
I certify, under penalty of perjury, that Contractor is registered with the Department of Industrial Relations pursuant to Labor Code section 1725.5.
Contractor’s Department of Industrial Relations registration number is _________________.
Name & Title (print or type)
Date Signature
(Labor Code section 1725.5)
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
Christopher Flores, Regional Vice-President
1000052909
03 / 25 / 2024
Specification No. TM-2023-3
CONTRACT
CC Agreement 2024-14
CAM #4844-6202-6590 v1
CERTIFICATE REGARDING
WORKERS’ COMPENSATION
Contractor is aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers’ compensation or to undertake self - insurance in accordance with the provisions of that code, and Contractor will comply with such provisions before commencing the performance of the Work of this Contract.
Name & Title (print or type)
Date Signature
Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1
Christopher Flores, Regional Vice-President
03 / 25 / 2024
Specification No. TM-2023-3
BID PROPOSAL
LIST OF SUBCONTRACTORS
WORK IDENTIFICATION: TM-2023-3,CAMARILLO VIDEO DETECTION PROJECT NAME AND ADDRESS OF BIDDER:
In compliance with the Subletting and Subcontracting Fair Practices Act, Public Contracts Code section 4100 and following, each subcontractor who will perform work or labor or render service to the bidder in or about the construction of the work or will specifically fabricate and install a portion of the work in an amount in excess of one half of one percent (0.5%) of the total bid sum or in the case of bids or offers for the construction of streets or highways, including bridges, in excess of one-half of one percent (0.5%) of the total bid or $10,000, whichever is greater. (List only one subcontractor for each portion of the work as is defined by the bidder in this bid.) No other subcontractors may be used other than those specified without written approval of the City Engineer; such approval will be made upon showing by the contractor of good and sufficient cause.
Failure to specify a subcontractor or specifying more than one subcontractor for the same portion of work to be performed under the contract in excess of one-half of one percent (0.5%) of the total bid constitutes an agreement that the contractor is fully qualified and will perform that portion of the work. Any contractor who subcontracts for any portion of work not set forth herein, except as otherwise provided by Public Contract Code sections 4107 or 4109, will be subject to the penalties set forth in Public Contract Code sections 4110 and 4111.
Name/Address/State License
Number of Subcontractor
Department of Industrial
Relations Registration
Number* Items of Work
Portion of Work
(% of Contract Price)
% of Total Contract
Price by Subcontract
% of Total Contract
Price by Contractor
*Pursuant to Division 2, Part 7, Chapter 1 (commencing with section 1720 including section 1725.5) of the Labor Code Doc ID: 00cad8354fc9b56e48be4759d61a42b583f0b4e1