CASTRO 73802 Dinah Shore Dr. Palm Desert, CA 92211
Office: 760-202-0042 | Fax: 760-992-5204
www.CastroRoofinglnc.com
ROOFING NE
License #828478
City of Cathedral City
68700 Ave. Lalo Guerrero
Cathedral City, CA 92234
Re: Roof Estimate
Century Park
Cathedral City, CA 92234
Thank you for the opportunity to submit a proposal for your roofing needs at the above referenced property.
Castro Rooting, Inc. is a full service roofing company. We have over 30 years of experience. We are a family owned and operated company that delivers in honesty, integrity and quality. We value the opportunity to earn your business.
Work Description
Completely remove existing roofs and haul away.
Inspect for dry-rot, any found will be replaced at a rate of $86.00 per (4x8x½) sheet upon owner's approval. The sheathing cost is not included in this contract and will be an extra cost as we cannot foresee the condition of the sheathing. Once the roofing system is removed we can then determine how many sheets will need to be replaced, if any. Fascia to be replaced with primed resawn fascia at and additional cost of $18 a foot.
- Substrate to be inspected for loose or non-flush nails any found will be completely pulled out and re- nailed with new nails.
- Substrate to be cleaned and free of all debris or any other foreign matter that may deplete the new roof system
- Install new 2x2 perimeter edge metal as needed, brown, white, grey or galvanized.
Install new Synthetic underlayment fastened to secure.
Install new Owens Corning Oakridge (standard colors) Title-24 cool roof shingles (130 MPH wind rated) lifetime warrantee to manufactures specifications. - Install new hip and ridge trim to enhance roof appearance - Clean all job related debris and haul away.
Contract Price
Owner shall pay contractor the fixed sum for the work to be performed under this contract, subject to additions and deductions, pursuant to change orders agreed upon in writing by the parties, and subject to "allowance" as provided in this paragraph.
Optional (THIS IS FOR AN EXTRA COST ON TOP OF THE CONTRACT PRICE LISTED ABOVE, IF YOU WOULD LIKE TO PROCEED WITH ANY OF THE OPTIONS PLEASE INITIALS NEXT TO THE ADDITIONAL COST.) Amount for Big Canopy: Nine Thousand, Five Hundred, Eighty-Two Dollars. ($9,582.00) initial Amount for three (3) Small Canopy: Eleven Thousand, Eight Hundred Dollars($11,800.00) initials TERM:
10% OF CONTRACT DUE UPON ACCEPTANCE OF CONTRACT, 50% DUE ONCE HALF OF THE PROJECT HAS BEEN COMPLETED AND REMAINING 40% DUE UPON COMPLETION, PAYMENT PLAN IS NOT PART OF THIS AGREEMENT. FINANCE FEES WILL APPLY TO ANY OUTSTANDING BALANCE.
_ INITIALS
City Of Cathedral City- Century Park (Shingles) Page 1 of 5 June 9, 2022 A SERVICE CHARGE OF ONE AND ONE-HALF PERCENT (1.5%) PER MONTH WILL BE ADDED TO ALL BALANCES OVER 30-DAYS.
FOR ALL CREDIT/DEBIT CARD PAYMENT THERE IS AN ADDITIONAL 3% FOR EACH PROCESSED AMOUNT.
FIVE (5) YEAR GUARANTEE ON WORKMANSHIP OVER AREAS COMPLETED BY CASTRO ROOFING, INC. ONLY. GUARANTEE BON AL THE L AMENT I RECENE ONTRACT SAL NOT TE ARE FOR SECULA, INCORVIL OR.
CONSEQUENTIAL DAMAGES.
THIS GUARANTEE SHALL BE NULL AND VOID IF ANY TYPE OF WORK IS PERFORMED ON THE ROOF BY OTHERS, SUCH AS BUT NOT
LIMITED TO, MAINTENANCE OR REPAIRS ON THE ROOF, SEALING OF HOLES, A/C DUCTING, PLUMBING, SOLAR PENETRATIONS WALKING ON THE ROOF AND IF CASTRO ROOFING INC. IS NOT (A FEE MAY APPLY) IMMEDIATELY NOTIFIED TO INSPECT THE ROOF AT THE TIME THE WORK IS PERFORMED.
THIS PROPOSAL DOES NOT INCLUDE ANY WATER TESTING AFTER WORK IS COMPLETED, IF WATER TEST IS REQUESTED THERE IS AN ADDITIONAL FEE THAT WILL APPLY.
MAINTAINING THE ROOFS IS ESSENTIAL IN ORDER TO ACHIEVE NORMAL LIFE EXPECTANCY CASTRO ROOFING, INC HIGHLY RECOMMENDS SETTING UP A PROPER MAINTENANCE PROGRAM FOR AN ADDITIONAL FEE.
THIS PROPOSAL WILL BE NULL AND VOID AFTER 15-DAYS FROM CONTRACT DATE.
OWNER HAS THE RIGHT TO CANCEL THIS CONTRACT AFTER ACCEPTANCE UP TO THREE (3) DAYS OF ACCEPTED CONTRACT AND MUST FILL OUT AND SEND IN NOTICE OF CANCELLATION.
ALL DEBRIS CAUSED FROM THE ABOVE WORK WILL BE DISPOSED AND DISCARDED.
JOB TO BE STARTED IN A TIMELY MANNER ACCORDING TO CURRENT WORK SCHEDULE AND WEATHER PERMITTING.
DEPENDING ON THICKNESS OF EXISTING SHEATHING NAILS MAY PENETRATE THROUGH THE PLYWOOD ON OUTSIDE OVERHANG.
ESTIMATE DOES NOT INCLUDE DISCONNECTING AND RECONNECTING ANY ELECTRICAL, PLUMBING, GAS LINES AND MECHANICAL EQUIPMENT UNLESS OTHERWISE SPECIFIED.
WE PURPOSE TO FURNISH AND APPLY LABOR, MATERIALS, PERMITS (IF APPLICABLE) TRANSPORTATION AND TOOLS NECESSARY FOR COMPLETION OF ACCEPTED ROOFING CONTRACT WORK.
CONTRACTOR'S SCOPE OF WORK SHALL NOT INCLUDE THE IDENTIFICATION, DETECTION, ABATEMENT, ENCAPSULATION OR REMOVAL OF ASBESTOS OR SIMILAR HAZARDOUS SUBSTANCES INCLUDING MOLD, MILDEW AND INFESTATION OF RODENTS. IF
CONTRACTOR ENCOUNTERS ANY SUCH PRODUCTS, MATERIALS OR CONDITIONS IN THE COURSE OF PERFORMING ITS WORK, OR
IF SUCH HAZARDOUS MATERIALS ARE ENCOUNTERED BY ANY OTHER FIRM PERFORMING WORK AT THE JOBSITE AND
CONTRACTOR DETERMINES THAT SUCH MATERIALS PRESENT A HAZARD TO ITS EMPLOYEES, CONTRACTOR SHALL HAVE THE
RIGHT TO DISCONTINUE ITS WORK AND REMOVE ITS EMPLOYEES FROM THE JOBSITE UNTIL SUCH PRODUCTS OR MATERIALS,
AND ANY HAZARDS CONNECTED THEREWITH, ARE LOCATED AND ABATED, ENCAPSULATED OR REMOVED, OR IT IS
DETERMINED THAT NO HAZARD EXISTS (AS THE CASE MAY REQUIRE), AND CONTRACTOR SHALL RECEIVE AN EXTENSION OF
TIME TO COMPLETE ITS WORK HEREUNDER AND COMPENSATION FOR DELAYS ENCOUNTERED AS A RESULT OF SUCH SITUATION AND CORRECTION. DUE TO THE POSSIBILITY OF MOLD, MILDEW AND RODENTS BEING PRESENT BEFORE, DURING OR AFTER OUR
WORK, CONTRACTOR'S SCOPE OF WORK SHALL NOT INCLUDE THE IDENTIFICATION, DETECTION OR THE REMOVAL OF MOLD, MILDEW AND RODENTS. OWNER AGREES TO HOLD CONTRACTOR HARMLESS, AND SHALL INDEMNIFY CONTRACTOR HARMLESS
FOR ANY MOLD OR RODENT RELATED CLAIMS IN THE FUTURE
ANY CHANGES TO ORIGINAL CONTRACT WILL BE ADJUSTED AND MUTUALLY AGREED BEFORE CONTRACTOR PERFORMS WORK AND SUBMITTED IN A WRITTEN FORM OF A CHANGE ORDER.
DURING THE ROOFING PROJECT CONTRACTOR WILL MAKE ALL ATTEMPTS TO MINIMIZE, BUT WILL NOT BE RESPONSIBLE FOR DIRT, ROCK, MATERIAL, OR DEBRIS THAT MAY FALL INTO LIVING AREAS.
IF OWNER SHOULD CAUSE DELAY TO THE CONTRACT WORK, OWNER SHALL BE LIABLE FOR ALL LOSSES, COST, EXPENSES,
LIABILITIES AND DAMAGES, INCLUDING CONSEQUENTIAL DAMAGES AND LIQUIDATED DAMAGES, SUSTAIN BY CONTRACTOR, OR FOR WHICH CONTRACTOR MAYBE LIABLE TO ANY OTHER PARTY BECAUSE OF OWNER DEFAULT.
CONTRACTOR DOES NOT ASSUME ANY RESPONSIBILITY FOR CORRECTION OF EXISTING CODE VIOLATION OR FOR REPAIRS OF ANY EXISTING STRUCTURAL DEPECT UNLESS SPECIFIED IN THE PROPOSAL. CONTRACTOR DOES NOT INCLUDI PROPOSAL DOES NOT INCLUDE ANY BEFORE OR AFTER PHOTOS. IF REQUIRED THEY MUST BE REQUESTED PRIOR TO WORK
COMMENCEMENT FOR AN ADDITIONAL FEE
INSURANCE: CASTRO ROOFING, INC. SHALL SECURE, PAY THE PREMIUM FOR, AND KEEP IN FORCE UNTIL EXPIRATION OF THIS
AGREEMENT WORKER'S COMPENSATION INSURANCE, GENERAL LIABILITY INSURANCE, AND AUTO LIABILITY INSURANCE WITH LIMITS NOT LESS THAN ONE MILLION DOLLARS ($1,000,000.00): GENERAL LIABILITY WITH ONE MILLION DOLLARS ($1,000,000) PER OCCURRENCE AND TWO MILLION DOLLARS ($2,000,000.00) AGGREGATE, AUTO LIABILITY AT ONE MILLION DOLLARS COMBINED SINGLE LIMIT ($1,000,000), AND WORKERS COMP AT A ONE MILLION DOLLAR ($1,000,000) LIMIT.
ANY ADDITIONAL INSURANCE OR ENDORSEMENTS REQUIRED FOR THIS PROJECT WILL BE THE RESPONSIBILITY OF THE CONTRACTOR AND/OR PERSON (S) OR ENTITY (OWNER OR OWNER'S AGENT) TO INFORM CASTRO ROOFING, INC. PRIOR TO THE ACCEPTANCE OF CONTRACT. THISWILL BE AT AN ADDITIONAL COST TO THE PERSON REQUIRING THE ADDITIONAL INSURANCE OR ENDORSEMENTS. (NOT INCLUDED IN THIS PRICE). OUR LIABILITY POLICY IS BASED ON A YEARLY RENEWAL, PLEASE NOTE THAT IF THE CONTRACT GOES BEYOND THE DECEMBER 1 OF ANY YEAR A NEW POLICY WILL GO INTO PLACE WITH THE REGULAR LIMITS AND WILL NOT INCLUDE THE ADDITION ENDORSEMENTS OR LIMITS. THE SAME APPLIES FOR AUTO AND WORKERS COMPENSATION INSURANCE ON THE YEARLY EXPIRATION DATE.
IN THE EVENT A LAWSUIT IS BROUGHT TO ENFORCE THE TERMS OF THE CONTRACT, THE PREVAILING PARTY SHALL RECOVER ALL COSTS EXPENDED, INCLUDING ANY ATTORNEY FEES AS AN ELEMENT OF COST. IF A COLLECTION AGENCY OR ATTORNEY IS USED TO RECOVER FUNDS OWNER/AGENT WILL BE RESPONSIBLE FOR ALL ADDITIONAL FEES INCURRED.
INITIALS
City Of Cathedral City- Century Park (Shingles) Page 2 of 5 June 9, 2022 INFORMATION ABOUT THE CONTRACTS STATE LICENSE BOARD (CSLB). CSLB IS THE STATE CONSUMER PROTECTION AGENCY THAT LICENSES AND REGULATES CONSTRUCTION CONTRACTORS. CONTACT CS FOR INFORMATION ABOUT THE LICENSED
CONTRACTOR YOU ARE CONSIDERING, INCLUDING INFORMATION ABOUT DISCLOSABLE COMPLAINTS, DISCIPLINARY ACTIONS AND CIVIL JUDGMENTS THAT ARE REPORTED TO CSLB. USE ONLY LICENSED CONTRACTORS. IF YOU FILE A COMPLAINT
AGAINST A LICENSED CONTRACTOR WITHIN THE LEGAL DEADLINE (USUALLY FOUR YEARS), CSIB HAS AUTHORITY TO INVESTIGATE THE COMPLAINT. IF YOU USE AN UNLICENSED CONTRACTOR, CSL MAY NOT BE ABLE TO HELP YOU RESOLVE YOUR COMPLAINT. YOUR ONLY REMEDY MAY BE IN CIVIL COURT, AND YOU MAY BE LIABLE FOR DAMAGES ARISING OUT OF ANY INJURIES TO THE UNLICENSED CONTRACTOR OR THE UNLICENSED CONTRACTOR'S EMPLOYEES. FOR MORE INFORMATION:
VISIT CLB'S WEBSITE AT WWW.CSLB.CA.GOV CALL: CLB AT I-800-321-CSLB (2752) WRITE CSB AT P.O. BOX 2600, SACRAMENTO.
CA 95826
IF THIS CONTRACT MEETS WITH YOUR APPROVAL, PLEASE INDICATE YOUR ACCEPTANCE BY INITIALING ALL PAGES (BOTTOM RIGHT) AND SIGNING (BOTTOM RIGHT) LAST PAGE AND RETURNING TO OUR OFFICE BY EMAIL, MAIL, OR FAX. WE LOOK FORWARD TO WORKING WITH YOU.
YOU ARE ENTITLED TO A COMPLETELY FILLED IN COPY OF THIS AGREEMENT, SIGNED BY BOTH YOU AND THE CONTRACTOR,
BEFORE ANY WORK MAY BE STARTED
-_ INITIALS
City Of Cathedral City- Century Park (Shingles) Page 3 of 5 June 9, 2022 THREE (3) DAY NOTICE OF CANCELLATION
You may cancel this transaction, without any penalty or obligation, within three (3) business days from the above date.
the contra vi can l, thy sele of gor cart olation anil wil return any down payment made by you under If you cancel, you must make available to the seller at your residence any material, in substantially as good condition as when received, and in a timely manner, any goods delivered to you under this contract. Any estocking fees will be non-refundable
If you do make the goods available to the seller and the seller does not pick them up within 20-days of You dat of your the co avalail to the my ear ordi are of herod idols any ither abigain do so, then you remain liable for performance of all obligations under the contract.
To cancel this transaction, e-mail, fax, or mail a signed and dated copy of this cancellation notice, or any other written notice.
Reason for Cancellation:
I hereby cancel this contract on: For the property located at:
(DATE) (ADDRESS)
(ADDRESS)
(NAME OF OWNER)
(SIGNATURE)
INITIALS
City Of Cathedral City- Century Park (Shingles) Page 4 of 5 June 9, 2022