Item 19 – Approve Amendment 1 to the Power Purchase Agreement (PPA) with Resurgence Solar I, LLC related to price and terms. — Valley Clean Energy Board of Directors, July 14, 2022

Item 19
1 VALLEY CLEAN ENERGY ALLIANCE
Staff Report – Item 19
TO: Board of Directors
FROM: Mitch Sears, Executive Officer
Gordon Samuel, Assistant General Manager & Director of Power Services SUBJECT: Approve Amendment 1 to Resurgence Solar I, LLC Power Purchase Agreement DATE: July 14, 2022

RECOMMENDATION
Adopt a resolution authorizing the Executive Officer to (1) execute Amendment 1 to the Resurgence Solar 1 Power Purchase Agreement (PPA) substantially in the form attached and (2) authorizes the Executive Officer, in consultation with General Counsel, to make minor changes to the PPA Amendment 1 so long as the term and price are not changed.

BACKGROUND
In January 2021, the VCE Board approved the Resurgence Solar I PPA which is a 90 MW PV field combined with a 75 MW (300 MWhs) lithium-ion battery storage system project located in San Bernadino County, California. The project has received all necessary permits and commenced construction in March 2022.

In May 2022, the counterparty approached VCE identifying numerous challenges facing the project and the broader renewable industry. Unprecedented global cost pressures, the U.S.

Department of Commerce’s investigation into circumvention of Anti-Dumping/Countervailing Duties of photovoltaic modules (“Circumvention Investigation”), Uyghur Forced Labor Prevention Act, etc. have put undo schedule and cost pressures on the project.

Based on anecdotal evidence, staff has confirmed that these factors are present and effecting PPA’s of a similar vintage across the renewable energy landscape.

VCE agreed to consider the request of the counterparty to amend the PPA and staff has been working on an amendment that is amenable to both parties.

COUNTERPARTY
NextEra Energy Inc. subsidiary, NextEra Energy Resources is the world’s largest developer of renewable energy from wind and solar. NextEra has a proven record of success and extensive experience in developing, constructing and operating wind, solar, and battery storage projects across North America. The company has been generating clean energy for more than 35 years and is the largest generator of wind and solar power in North America. Through its subsidiaries, Item 19
2 NextEra owns and operates 124 wind facilities with a total generating capacity of 16,280 MW, as well as 34 utility-scale solar facilities with a generating capacity of 3,156 MW. NextEra has constructed dozens of renewable projects as big or larger than the Resurgence Solar I project and has developed and constructed some of the largest storage projects in the industry.

NextEra is a large scale generator of renewable energy and is a major developer in energy storage. In the U.S. and Canada, NextEra has approximately 164 MW of energy storage projects in operation and over 2 GW of energy storage projects with signed long-term contracts currently under development.

In the state of California, NextEra owns and operates wind, solar, battery energy storage facilities and transmission assets in 20 counties. NextEra has executed long-term contracts for renewable energy supply with several California Community Choice Aggregators (CCAs) including Silicon Valley Clean Energy, Marin Clean Energy, CleanPowerSF, Sonoma Clean Power Authority, Clean Power Alliance of Southern California, and Central Coast Community Energy for solar, storage, and wind.

NextEra will develop, own and operate the Resurgence Solar I project.

PROJECT DESCRIPTION / PORTFOLIO
The Resurgence Solar I project will consist of a 90 MW PV field combined with a 75 MW (300 MWhs) lithium-ion battery storage system. The project will be part of a larger project that could be up to a 138 MWs. The existing “brownfield” site is the home of the SEGS project which was one of the original solar thermal sites built in the 1980’s. The legacy project ceased operation in 2019. NextEra plans to repurpose the site and decommission the SEGS assets and replace with PV + storage. The development plan required a conditional use permit from San Bernadino County as well as an approved decommissioning plan from the California Energy Commission (CEC), both of which have been received. Environmentally, the site is disturbed land with no wetlands, biological or cultural issues. NextEra is using the existing transmission infrastructure.

VCE will receive approximately 1/3rd of its annual needs from the renewable facility for 20 years. The competitively priced energy and capacity will allow VCE to secure stable pricing for both energy and resource adequacy. As illustrated in the below chart, the Resurgence project plays a critical role in VCE’s portfolio. The project provides a large portion of renewable energy which supports the Renewable Portfolio Standard (RPS) mandate, has a significant storage component supplying valuable resource adequacy (RA), and has operational flexibility allowing VCE’s customers to benefit economically.

Item 19
3 AMENDMENT
The amendment addresses adjustments to the PPA pricing, schedule, development security as well as an increase to the workforce development and local sustainability funds. As shown in the attached Amendment, the project continues to provide a large portion of renewable energy which supports VCE’s strategic goals and helps satisfy the RPS and other regulatory mandates.

The amended agreement also continues to provide a significant storage component which supplies valuable resource RA. Overall, based on staff’s assessment of market conditions, the amended agreement continues to supply economic power and RA to VCE and its customers.

CONCLUSION
Staff believes the terms of the amendment supports VCE’s policy objectives, help meet regulatory requirements, and are competitively priced. Staff recognizes the unique energy market conditions and has developed an amendment that is in the best interest of VCE’s customers for the near and long term.

Attachments

1. Amendment 1 to Resurgence Solar I LLC Power Purchase Agreement (redacted)

2. Resurgence Solar I LLC Power Purchase Agreement (redacted)

3. Resolution 2022-XXX – Amendment 1 to Resurgence Solar I LLC Power Purchase Agreement 0 100000
00000
300000
00000
00000
00000
00000
800000
900000
1000000
0 1 0 0 3 0 0 0 0 0 8 0 9 030
MWh
Annual RPS Posi on
aseload
Willow Springs Solar Storage
Gibson Solar Storage
Resurgence Solar Storage
Putah Creek Solar Storage
A uamarine Solar
Indian Valley ydro
Short Term RECs
VCE Retail Load
RPS Re uirement
Renewable 13 18 1 8 83 9 9
39 renewable during compliance
period ( 0 re uirement)
AMENDMENT NO. 1 TO RENEWABLE POWER PURCHASE AGREEMENT
This Amendment No. 1 (the “Amendment”) to the Agreement (as defined below), is dated as of July __, 2022 (the “Amendment Effective Date”), between Valley Clean Energy Alliance, a California joint powers authority (“Buyer”), and Resurgence Solar I, LLC, a Delaware limited liability company (“Seller”). Seller and Buyer are each a “Party” and together the “Parties”.

RECITALS
A. The Parties entered into that certain Renewable Power Purchase Agreement, dated as of January 21, 2021 (the “Agreement”).

B. Seller has claimed significant cost increases and associated delays in achieving Commercial Operation on or before the Guaranteed Commercial Operation Date.

C. The Parties intend to resolve all matters with respect to Seller’s cost increases and Commercial Operation delays on the terms set forth herein.

NOW, THEREFORE, in consideration of the foregoing and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties agree as follows:

1. Definitions. Capitalized terms used and not defined in this Amendment have the respective meanings assigned to them in the Agreement.

2. Amendments to the Agreement.
(a) The date set forth for the Milestone for “Expected Commercial Operation Date” of “12/31/2022” on the Cover Sheet of the Agreement shall be deleted and replaced with “5/15/2023”.
(b) The date set forth for the Milestone for “Guaranteed Commercial Operation Date” of “12/31/2022” on the Cover Sheet of the Agreement shall be deleted and replaced with “5/15/2023”.
(c) The date set forth for the “RA Guarantee Date” on the Cover Sheet shall be deleted and replaced with “the later of (i) July 1, 2023 or (ii) the first day of the first Showing Month that commences at least thirty (30) days after the Commercial Operation Date”.
(d) The “Renewable Rate” portion of the “Contract Price” on the Cover Sheet of the Agreement shall be deleted and replaced with the following table:

Contract Year Renewable Rate
1 – 20
2 (e) The “Development Security” portion of “Security” on the Cover Sheet of the Agreement,
Development Security required hereby pursuant to Section 3 of this Amendment.
(f) A new Section 4.10(h) is added to the Agreement as follows:

Seller and, if applicable, its successors, represents and warrants that throughout the Delivery Term of this Agreement the Renewable Energy Credits transferred to Buyer conform to the definition and attributes required for compliance with the California Renewables Portfolio Standard, as set forth in California Public Utilities Commission Decision 08-08-028, and as may be modified by subsequent decision of the California Public Utilities Commission or by subsequent legislation. To the extent a change in law occurs after execution of this Agreement that causes this representation and warranty to be materially false or misleading, it shall not be an Event of Default if Seller has used commercially reasonable efforts to comply with such change in law.
(g) Section 11.6 of the Agreement, regarding “Limitation on Seller’s Ability to Make or Agree to Third-Party Sales from the Facility after Early Termination Date”, shall be amended by replacing .
(h) Section 11.9 of the Agreement, regarding “Seller Pre-COD Termination”, shall be deleted in its entirety and replaced with the following:

At any time prior to the Commercial Operation Date, Seller may for any reason, by Notice to Buyer pursuant to this Section 11.9, terminate this Agreement. As Buyer’s sole right and remedy (and Seller’s sole liability and obligation) arising out of any such termination under this Section 11.9, Buyer shall be entitled (A) to liquidate and retain all Development Security and (B) to collect from Seller (and Seller shall be obligated to pay to Buyer) the total amount of all Delay Damages accrued and unpaid as of the Agreement termination date; provided, in no event shall the sum of (A) and (B) exceed an amount equal to
(i) Section 13.4 of the Agreement, regarding “Workforce Development”, shall be amended by (i) replacing “twenty thousand dollars ($20,000)” with “thirty thousand dollars ($30,000), and (ii) replacing “two hundred thousand dollars ($200,000)” with “three hundred thousand dollars ($300,000)”. 3 (j) Section 13.5 of the Agreement, regarding “Local Sustainability”, shall be amended by (i) replacing “ten thousand dollars ($10,000)” with “fifteen thousand dollars ($15,000), and (ii) replacing “one hundred thousand dollars ($100,000)” with “one hundred fifty thousand dollars ($150,000)”.
(k) Section 2(b) of Exhibit B of the Agreement shall be deleted in its entirety and replaced with the following:

Seller may extend the Guaranteed Commercial Operation Date by paying Commercial Operation Delay Damages in advance to Buyer for each day Seller desires to extend the Guaranteed Commercial Operation Date. On or before the date that is ten (10) days prior to the then-current Guaranteed Commercial Operation Date Seller shall provide Notice and payment to Buyer of the Commercial Operation Delay Damages for the number of days Seller wishes to extend the Guaranteed Commercial Operation Date. If Seller extends the Guaranteed Commercial Operation Date through the payment of Commercial Operation Delay Damages and Seller achieves Commercial Operation prior to the Guaranteed Commercial Operation Date as extended by the payment of such Commercial Operation Delay Damages, Buyer shall refund to Seller the Commercial Operation Delay Damages for each day that Seller achieves Commercial Operation prior to the Guaranteed Commercial Operation Date times the Commercial Operation Delay Damages, not to exceed the total amount of Commercial Operation Delay Damages paid by Seller pursuant to this Section 2(b). To the extent a Development Cure Period overlaps with any days for which Seller has paid to Buyer Commercial Operation Delay Damages to extend the Guaranteed Commercial Operation Date, then Buyer shall refund to Seller the Commercial Operation Delay Damages for each day that is covered by such Development Cure Period, not to exceed the total amount of Commercial Operation Delay Damages paid by Seller pursuant to this Section 2(b). For avoidance of doubt, this Section 2(b) does not limit Seller’s right to claim a Development Cure Period pursuant to Section 4 of this Exhibit B that would extend the Guaranteed Commercial Operation Date past the period of time for which Seller previously paid Commercial Operation Delay Damages to extend the Guaranteed Commercial Operation Date; nor does this Section 2(b) limit Seller’s right to pay additional Commercial Operation Delay Damages to further extend the Guaranteed Commercial Operation Date past the date on which a Development Cure Period has concluded.
(l) Section 4(a) of Exhibit B of the Agreement, regarding “Extension of the Guaranteed Dates”, shall be deleted in its entirety and replaced with the following: “Reserved”. (m) Section 4(b) of Exhibit B of the Agreement, regarding “Extension of the Guaranteed Dates”, shall be deleted in its entirety and replaced with the following:
a Force Majeure Event occurs, provided, however, that Seller may not claim a Force Majeure Event due to any circumstance known by Seller at the time of the Amendment Effective Date, including any of the circumstances identified in 4 Attachment 1 to the Amendment, which is incorporated into the Agreement by this reference; or
(n) Section I.(C.) of Exhibit Q of the Agreement, regarding “Charge and Discharge Rates”, shall be amended by replacing each of the listed “75 MW/s” amounts under the “Ramp Rate (MW/s) Description” with “16 MW/s”.

3. To secure its obligations under the
Agreement, as amended hereby, Seller shall deliver to Buyer the Development Security required hereunder within ten (10) days after the Amendment Effective Date.

4. Limited Effect. Except as expressly provided in this Amendment, all of the terms and provisions of the Agreement are and will remain in full force and effect and are hereby ratified and confirmed by the Parties. Without limiting the generality of the foregoing, the amendments contained herein will not be construed as an amendment to or waiver of any other provision of the Agreement or as a waiver of or consent to any further or future action on the part of either Party that would require the waiver or consent of the other Party. On and after the Effective Date of this Amendment, each reference in the Agreement to “this Agreement,” “the Agreement,” “hereunder,” “hereof,” “herein” or words of like import will mean and be a reference to the Agreement as amended by this Amendment.

5. Miscellaneous.
(a) This Amendment is governed by and construed in accordance with, the laws of the State of California, without regard to the conflict of laws provisions of such State. (b) This Amendment shall inure to the benefit of and be binding upon each of the Parties and each of their respective successors and permitted assigns. (c) The headings in this Amendment are for reference only and do not affect the interpretation of this Amendment.
(d) This Amendment may be executed in counterparts, each of which is deemed an original, but all of which constitutes one and the same agreement. Delivery of an executed counterpart of this Amendment electronically or by facsimile shall be effective as delivery of an original executed counterpart of this Amendment. (e) This Amendment constitutes the sole and entire agreement between the Parties with respect to the subject matter contained herein, and supersedes all prior and contemporaneous understandings, agreements, representations and warranties, both written and oral, with respect to such subject matter.
(f) Each Party shall pay its own costs and expenses in connection with this Amendment (including the fees and expenses of its advisors, accounts and legal counsel). 5 [Signature Page Follows]
6 IN WITNESS WHEREOF, the Parties have executed this Amendment effective as of the date first written above.
“SELLER:”

RESURGENCE SOLAR I, LLC
By:

Printed Name:

Title:
“BUYER:”

VALLEY CLEAN ENERGY ALLIANCE
By:

Printed Name:

Title:
7 ATTACHMENT 1

CIRCUMSTANCES FOR WHICH FORCE MAJEURE NOT ALLOWED
Seller’s inability to obtain sufficient equipment, materials or other resources to build or operate the Facility resulting in delays and/or inability to timely achieve the Guaranteed Commercial Operation Date arising from the decision of the U.S. Department of Commerce issued on March 28, 2022, to initiate an anti-circumvention investigation in Crystalline Silicon Photovoltaic Cells, Whether or Not Assembled into Modules, from the People's Republic of China, Petition filed February 8, 2022 by Auxin Solar, Inc. in four separate DOC dockets: A-570-979 Malaysia; Thailand; Cambodia; and Vietnam.

Seller is aware of (i) rulemaking in connection with the Uyghur Forced Labor Prevention Act enacted on December 23, 2021, or (ii) the Hoshine Silicon Industry Withhold Release Order, which could ultimately have a negative impact on Seller and the Facility/project.

EXECUTION VERSION

RENEWABLE POWER PURCHASE AGREEMENT

COVER SHEET
Seller: Resurgence Solar I, LLC
Buyer: Valley Clean Energy Alliance, a California joint powers authority Description of Facility: A solar photovoltaic electric generating facility with a net nameplate capacity of 90 MW AC coupled with a lithium ion (Li-Ion) battery storage facility with a net nameplate capacity of 75 MW AC / 300 MWh located near the City of Boron within San Bernardino County, California, as described further in Exhibit A.

Milestones:

Milestone Expected Date for
Completion
Execute Interconnection Agreement
Procure major equipment
Obtain federal and state discretionary permits
Expected Construction Start Date
Guaranteed Construction Start Date
Expected Commercial Operation Date
Guaranteed Commercial Operation Date 12/31/2022
Delivery Term: Twenty (20) Contract Years
Delivery Term Expected Energy:

Contract Year Expected Energy (MWh)
1 2
3 4
5 6
7 8
9 10
11 12
13 14
15 16
17 18
19 20
Guaranteed Capacity: 165 MW of total Facility capacity
Guaranteed Storage Capacity: 75 MW of Installed Storage Capacity at four (4) hours of continuous discharge
Guaranteed PV Capacity: 90 MW of Installed PV Capacity
Guaranteed Efficiency Rate:

Contract Year Guaranteed Efficiency Rate
1 2
3 4
5 6
7 8
9 10
11 12
13 14
15 16
17 18
19 20
RA Guarantee Date: Commercial Operation Date
Contract Price:

The Renewable Rate shall be:

Contract Year Renewable Rate
1 – 20
The Storage Rate shall be:

Contract Year Storage Rate
1 – 20
Product:
☒ PV Energy
☒ Discharging Energy
☒ Green Attributes
☒ Installed Storage Capacity and Effective Storage Capacity ☒ Ancillary Services
☒ Capacity Attributes
Scheduling Coordinator: Buyer
Security:

Development Security:

Performance Security:

Guarantor:

TABLE OF CONTENTS
Page
i
ARTICLE 1 DEFINITIONS ........................................................................................................ 1

1.1 Contract Definitions............................................................................................... 1

1.2 Rules of Interpretation ......................................................................................... 25 ARTICLE 2 TERM; CONDITIONS PRECEDENT.................................................................. 26

2.1 Contract Term. ..................................................................................................... 26

2.2 Conditions Precedent ........................................................................................... 26

2.3 Development; Construction; Progress Reports.................................................... 27

2.4 Remedial Action Plan .......................................................................................... 27 ARTICLE 3 PURCHASE AND SALE...................................................................................... 28

3.1 Purchase and Sale of Product............................................................................... 28

3.2 Sale of Green Attributes....................................................................................... 28

3.3 Imbalance Energy. ............................................................................................... 28

3.4 Ownership of Renewable Energy Incentives....................................................... 28

3.5 Future Environmental Attributes. ........................................................................ 29

3.6 Test Energy. ......................................................................................................... 29

3.7 Capacity Attributes. ............................................................................................. 29

3.8 Resource Adequacy Failure ................................................................................. 30

3.9 CEC Certification and Verification. .................................................................... 30

3.10 Eligibility. ............................................................................................................ 31

3.11 California Renewables Portfolio Standard........................................................... 31

3.12 Compliance Expenditure Cap. ............................................................................. 31

3.13 Project Configuration........................................................................................... 32 ARTICLE 4 OBLIGATIONS AND DELIVERIES................................................................... 32

4.1 Delivery................................................................................................................ 32

4.2 Title and Risk of Loss.......................................................................................... 33

4.3 Forecasting........................................................................................................... 33

4.4 Dispatch Down/Curtailment. ............................................................................... 34

4.5 Energy Management ............................................................................................ 35

4.6 Reduction in Delivery Obligation........................................................................ 37

4.7 Guaranteed Energy Production............................................................................ 38

4.8 Storage Facility Availability; Ancillary Services................................................ 39

4.9 Storage Facility Testing ....................................................................................... 40

4.10 WREGIS .............................................................................................................. 41 ARTICLE 5 TAXES .................................................................................................................. 43

5.1 Allocation of Taxes and Charges......................................................................... 43

5.2 Cooperation.......................................................................................................... 43 ARTICLE 6 MAINTENANCE OF THE FACILITY................................................................ 43

6.1 Maintenance of the Facility. ................................................................................ 43

6.2 Maintenance of Health and Safety....................................................................... 43

6.3 Shared Facilities................................................................................................... 44 ii
ARTICLE 7 METERING........................................................................................................... 44

7.1 Metering............................................................................................................... 44

7.2 Meter Verification................................................................................................ 45 ARTICLE 8 INVOICING AND PAYMENT; CREDIT............................................................ 45

8.1 Invoicing. ............................................................................................................. 45

8.2 Payment................................................................................................................ 45

8.3 Books and Records. ............................................................................................. 46

8.4 Payment Adjustments; Billing Errors. ................................................................. 46

8.5 Billing Disputes. .................................................................................................. 46

8.6 Netting of Payments............................................................................................. 47

8.7 Seller’s Development Security. ........................................................................... 47

8.8 Seller’s Performance Security.............................................................................. 47

8.9 First Priority Security Interest in Cash or Cash Equivalent Collateral ................ 47

8.10 Buyer’s Financial Covenants............................................................................... 48 ARTICLE 9 NOTICES .............................................................................................................. 49

9.1 Addresses for the Delivery of Notices................................................................. 49

9.2 Acceptable Means of Delivering Notice.............................................................. 50 ARTICLE 10 FORCE MAJEURE............................................................................................. 50

10.1 Definition ............................................................................................................. 50

10.2 No Liability If a Force Majeure Event Occurs .................................................... 51

10.3 Notice................................................................................................................... 51

10.4 Termination Following Force Majeure Event...................................................... 51 ARTICLE 11 DEFAULTS; REMEDIES; TERMINATION..................................................... 52

11.1 Events of Default ................................................................................................. 52

11.2 Remedies; Declaration of Early Termination Date.............................................. 55

11.3 Damage Payment; Termination Payment ............................................................ 55

11.4 Notice of Payment of Termination Payment or Damage Payment...................... 56

11.5 Disputes with Respect to Termination Payment or Damage Payment ................ 57

11.6 Limitation on Seller’s Ability to Make or Agree to Third-Party Sales from the Facility after Early Termination Date. ........................................................... 57

11.7 Rights and Remedies Are Cumulative................................................................. 57

11.8 Mitigation............................................................................................................. 57

11.9 Seller Pre-COD Termination. .............................................................................. 58 ARTICLE 12 LIMITATION OF LIABILITY AND EXCLUSION OF WARRANTIES ........ 58

12.1 No Consequential Damages................................................................................. 58

12.2 Waiver and Exclusion of Other Damages............................................................ 58 ARTICLE 13 REPRESENTATIONS AND WARRANTIES; AUTHORITY.......................... 59

13.1 Seller’s Representations and Warranties. ............................................................ 59

13.2 Buyer’s Representations and Warranties. ............................................................ 60

13.3 General Covenants. .............................................................................................. 61

13.4 Workforce Development...................................................................................... 61 iii

13.5 Local Sustainability. ............................................................................................ 61 ARTICLE 14 ASSIGNMENT.................................................................................................... 62

14.1 General Prohibition on Assignments. .................................................................. 62

14.2 Collateral Assignment.......................................................................................... 62

14.3 Permitted Assignment by Seller........................................................................... 62

14.4 Permitted Transfer by Seller................................................................................ 63

14.5 Shared Facilities; Portfolio Financing. ................................................................ 63 ARTICLE 15 DISPUTE RESOLUTION................................................................................... 63

15.1 Governing Law. ................................................................................................... 63

15.2 Dispute Resolution............................................................................................... 63

15.3 Attorneys’ Fees. ................................................................................................... 63 ARTICLE 16 INDEMNIFICATION ......................................................................................... 64

16.1 Indemnification. ................................................................................................... 64

16.2 Claims. ................................................................................................................. 64 ARTICLE 17 INSURANCE ...................................................................................................... 65

17.1 Insurance .............................................................................................................. 65 ARTICLE 18 CONFIDENTIAL INFORMATION................................................................... 66

18.1 Definition of Confidential Information................................................................ 66

18.2 Duty to Maintain Confidentiality......................................................................... 66

18.3 Irreparable Injury; Remedies. .............................................................................. 67

18.4 Further Permitted Disclosure. .............................................................................. 67

18.5 Press Releases...................................................................................................... 68 ARTICLE 19 MISCELLANEOUS............................................................................................ 68

19.1 Entire Agreement; Integration; Exhibits.............................................................. 68

19.2 Amendments. ....................................................................................................... 68

19.3 No Waiver............................................................................................................ 68

19.4 No Agency, Partnership, Joint Venture or Lease................................................. 68

19.5 Severability. ......................................................................................................... 69

19.6 Mobile-Sierra. ...................................................................................................... 69

19.7 Counterparts......................................................................................................... 69

19.8 Electronic Delivery. ............................................................................................. 69

19.9 Binding Effect...................................................................................................... 69

19.10 No Recourse to Members of Buyer. .................................................................... 69

19.11 Forward Contract. ................................................................................................ 70

19.12 Change in Electric Market Design....................................................................... 70

19.13 Further Assurances............................................................................................... 70 Exhibits:

Exhibit A Facility Description
Exhibit B Facility Construction and Commercial Operation Exhibit C Compensation
iv
Exhibit D Scheduling Coordinator Responsibilities
Exhibit E Progress Reporting Form
Exhibit F-1 Form of Monthly Expected Available Generating Facility Capacity Report Exhibit F-2 Form of Monthly Expected PV Energy Report
Exhibit F-3 Form of Monthly Expected Available Effective Storage Capacity Report Exhibit F-4 Form of Monthly Expected Available Storage Capability Report Exhibit G Guaranteed Energy Production Damages Calculation Exhibit H Form of Commercial Operation Date Certificate Exhibit I-1 Form of Installed Capacity Certificate
Exhibit I-2 Form of Effective Storage Capacity Certificate Exhibit J Form of Construction Start Date Certificate
Exhibit K Form of Letter of Credit
Exhibit L Form of Guaranty
Exhibit M Form of Replacement RA Notice
Exhibit N Notices
Exhibit O Storage Capacity Tests
Exhibit P Annual Storage Capacity Availability Calculation Exhibit Q Operating Restrictions
Exhibit R Metering Diagram
Exhibit S Form of Collateral Assignment Agreement

RENEWABLE POWER PURCHASE AGREEMENT
This Renewable Power Purchase Agreement (“Agreement”) is entered into as of January 21, 2021 (the “Effective Date”), between Buyer and Seller. Buyer and Seller are sometimes referred to herein individually as a “Party” and jointly as the “Parties.” All capitalized terms used in this Agreement are used with the meanings ascribed to them in Article 1 to this Agreement.

RECITALS
WHEREAS, Seller intends to develop, design, construct, own, and operate the Facility; and
WHEREAS, Seller desires to sell, and Buyer desires to purchase, on the terms and conditions set forth in this Agreement, the Product;
NOW THEREFORE, in consideration of the mutual covenants and agreements herein contained, and for other good and valuable consideration, the sufficiency and adequacy of which are hereby acknowledged, the Parties agree to the following:

ARTICLE 1

DEFINITIONS

1.1 Contract Definitions.

The following terms, when used herein with initial capitalization, shall have the meanings set forth below:
“AC” means alternating current.
“Accepted Compliance Costs” has the meaning set forth in Section 3.12(c). “Adjusted Energy Production” has the meaning set forth in Exhibit G. “Affiliate” means, with respect to any Person, each Person that directly or indirectly controls, is controlled by, or is under common control with such designated Person. For purposes of this definition and the definition of “Permitted Transferee”, “control” (including, with correlative meanings, the terms “controlled by” and “under common control with”), as used with respect to any Person, shall mean (a) the direct or indirect right to cast at least fifty percent (50%) of the votes exercisable at an annual general meeting (or its equivalent) of such Person or, if there are no such rights, ownership of at least fifty percent (50%) of the equity or other ownership interest in such Person, or (b) the right to direct the policies or operations of such Person.

Notwithstanding the foregoing, with respect to Seller, Affiliate shall include NextEra Energy Operating Partners, LP and NextEra Energy Partners, LP, and their respective direct or indirect Affiliate subsidiaries.
2 “After-Tax Basis” means, with respect to any payment received, or deemed to have been received, by any Person, the amount of such payment (the “Base Payment”), supplemented by a further payment (the “Additional Payment”) to such Person so that the sum of the Base Payment plus the Additional Payment will be equal to the Base Payment, after deduction of the amount of all taxes required to be paid by such Person in respect of the receipt or accrual of the Base Payment and the Additional Payment (taking into account any current or previous credits or deductions arising from the underlying event giving rise to the payment, the Base Payment and the Additional Payment). Such calculations shall be made on the assumption that the recipient is subject to Federal income taxation at the statutory rate applicable to corporations under subchapter C of the Internal Revenue Code of 1986, as amended, and subject to the highest state and local income tax rate then in effect for corporations in the states in which the Person is subject to taxation during the applicable fiscal year, and shall take into account the deductibility, if applicable (for Federal income tax purposes), of state and local income taxes.
“Agreement” has the meaning set forth in the Preamble and includes any Exhibits, schedules and any written supplements hereto, the Cover Sheet, and any designated collateral, credit support or similar arrangement between the Parties. “Ancillary Services” means spinning reserve, non-spinning reserve, regulation up, regulation down, black start, voltage support, and any other ancillary services that the Facility is capable of providing consistent with the Operating Restrictions, as each is defined in the CAISO Tariff.
“Annual Storage Capacity Availability” has the meaning set forth in Exhibit P. “Approved Forecast Vendor” means (x) any of CAISO or (y) any other vendor reasonably acceptable to both Buyer and Seller for the purposes of providing or verifying the forecasts under Section 4.3(d).
“Assignment Agreement” has the meaning set forth in Section 14.5. “Automated Dispatch System” or “ADS” has the meaning set forth in the CAISO Tariff. “Automatic Generation Control” or “AGC” has the meaning set forth in the CAISO Tariff.
“Availability Notice” means Seller’s availability forecasts issued pursuant to Section 4.3 with respect to the available Effective Storage Capacity and available Storage Capability. “Availability Standards” has the meaning set forth in the CAISO Tariff or such other similar term as modified and approved by FERC hereafter to be incorporated in the CAISO Tariff. “Bankrupt” or “Bankruptcy” means with respect to any entity, such entity that (a) files a petition or otherwise commences, authorizes or acquiesces in the commencement of a proceeding or cause of action under any bankruptcy, insolvency, reorganization or similar Law, (b) has any such petition filed or commenced against it which remains unstayed or undismissed for a period of ninety (90) days, (c) makes an assignment or any general arrangement for the benefit of creditors, (d) otherwise becomes bankrupt or insolvent (however evidenced), (e) has a liquidator, 3 administrator, receiver, trustee, conservator or similar official appointed with respect to it or any substantial portion of its property or assets, or (f) is generally unable to pay its debts as they fall due.
“Battery Charging Factor” means the percentage SOC of the Storage Facility after the first five (5) hours of the charging phase of the applicable Storage Capacity Test. “Battery Discharging Factor” means one (1) minus the percentage SOC of the Storage Facility after the first four (4) hours of the discharging phase of the applicable Storage Capacity Test.
“Business Day” means any day except a Saturday, Sunday, or a Federal Reserve Bank holiday in California. A Business Day begins at 8:00 a.m. and ends at 5:00 p.m. local time for the Party sending a Notice, or payment, or performing a specified action. “Buyer” has the meaning set forth on the Cover Sheet.
“Buyer Assignee” has the meaning set forth in Section 14.5. “Buyer Bid Curtailment” means the occurrence of both of the following:
(a) the CAISO provides notice to a Party or the Scheduling Coordinator for the Generating Facility, requiring the Party to deliver less PV Energy from the Generating Facility than the full amount of Energy forecasted in accordance with Section 4.3 to be produced from the Generating Facility for a period of time; and
(b) for the same time period as referenced in (a), the notice referenced in (a) results from Buyer or the SC for the Generating Facility:
(i) not having submitted a Self-Schedule or Energy Supply Bid for the MW subject to the reduction;
(ii) having submitted an Energy Supply Bid and the MW subject to the reduction were not awarded a schedule in connection with such Energy Supply Bid; or
(iii) having submitted a Self-Schedule for less than the full amount of Facility Energy forecasted to be generated by or delivered from the Facility.

If the Generating Facility is subject to a Planned Outage, Forced Facility Outage, Force Majeure Event and/or a Curtailment Period during the same time period as referenced in (a), then the calculation of Deemed Delivered Energy during such period shall not include any PV Energy that was not generated or stored due to such Planned Outage, Forced Facility Outage, Force Majeure Event or Curtailment Period.
4 “Buyer Curtailment Order” means the instruction from Buyer to Seller to reduce PV Energy from the Generating Facility by the amount, and for the period of time set forth in such instruction, for reasons unrelated to a Planned Outage, Forced Facility Outage, Force Majeure Event affecting the Facility and/or Curtailment Order.
“Buyer Curtailment Period” means the period of time, as measured using current Settlement Intervals, during which Seller reduces PV Energy from the Generating Facility pursuant to or as a result of (a) Buyer Bid Curtailment, (b) a Buyer Curtailment Order or (c) a Buyer Event of Default hereunder which directly causes Seller to be unable to deliver PV Energy to the Delivery Point; provided, that the duration of any Buyer Curtailment Period shall be inclusive of the time required for the Generating Facility to ramp down and ramp up. “Buyer Default” means an Event of Default of Buyer.
“Buyer Dispatched Test” has the meaning in Section 4.9(c). “Buyer’s Indemnified Parties” has the meaning set forth in Section 18.2. “Buyer’s WREGIS Account” has the meaning set forth in Section 4.10(a). “CAISO” means the California Independent System Operator Corporation or any successor entity performing similar functions.
“CAISO Certification” means the certification and testing requirements for a storage unit set forth in the CAISO Tariff that are applicable to the Facility, including certification and testing for all Ancillary Services, PMAX, and PMIN associated with such storage units, that are applicable to the Facility.
“CAISO Charges Invoice” has the meaning set forth in Exhibit D. “CAISO Dispatch” means any Charging Notice or Discharging Notice given by the CAISO to the Facility, whether through ADS, AGC or any successor communication protocol, communicating an Ancillary Service Award (as defined in the CAISO Tariff) or directing the Storage Facility to charge or discharge at a specific MW rate for a specified period of time or amount of MWh.
“CAISO Grid” has the same meaning as “CAISO Controlled Grid” as defined in the CAISO Tariff.
“CAISO Tariff” means the California Independent System Operator Corporation Agreement and Tariff, Business Practice Manuals (BPMs), and Operating Procedures, including the rules, protocols, procedures and standards attached thereto, as the same may be amended or modified from time to time and approved by FERC.
“Calculation Interval” has the meaning set forth in Exhibit P. “California Renewables Portfolio Standard” or “RPS” means the renewable energy program and policies established by California State Senate Bills 1038 (2002), 1078 (2002), 107 5 (2008), X-1 2 (2011), 350 (2015), and 100 (2018) as codified in, inter alia, California Public Utilities Code Sections 399.11 through 399.31 and California Public Resources Code Sections 25740 through 25751, as such provisions are amended or supplemented from time to time. “Capacity Attribute” means any current or future defined characteristic, certificate, tag, credit, or accounting construct associated with the amount of power that the Facility can generate and deliver to the Delivery Point at a particular moment and that can be purchased and sold under CAISO market rules, including Resource Adequacy Benefits. “Capacity Availability Factor” has the meaning set forth in Exhibit C. “Capacity Damages” means collectively Storage Capacity Damages and PV Capacity Damages.
“Capacity Test” or “CT” means the Commercial Operation Storage Capacity Test, Storage Capacity Test, or any other test conducted pursuant to Exhibit O. “CEC” means the California Energy Commission or its successor agency. “CEC Certification and Verification” means that the CEC has certified (or, with respect to periods before the date that is one hundred eighty (180) days following the Commercial Operation Date, that the CEC has pre-certified) that the Generating Facility is an Eligible Renewable Energy Resource for purposes of the California Renewables Portfolio Standard and that all PV Energy delivered to the Delivery Point qualifies as generation from an Eligible Renewable Energy Resource.
“CEC Precertification” means that the CEC has issued a precertification for the Facility indicating that the planned operations of the Facility would comply with applicable CEC requirements for CEC Certification and Verification.
“Change of Control” means, except in connection with public market transactions of equity interests or capital stock of Seller’s Ultimate Parent, any circumstance in which Ultimate Parent ceases to own, directly or indirectly through one or more intermediate entities, more than fifty percent (50%) of the outstanding equity interests in Seller; provided that in calculating ownership percentages for all purposes of the foregoing:
(a) any ownership interest in Seller held by Ultimate Parent indirectly through one or more intermediate entities shall not be counted towards Ultimate Parent’s ownership interest in Seller unless Ultimate Parent directly or indirectly owns more than fifty percent (50%) of the outstanding equity interests in each such intermediate entity; and (b) ownership interests in Seller owned directly or indirectly by any Lender (including any tax equity provider) shall be excluded from the total outstanding equity interests in Seller. “Charging Energy” means all PV Energy produced by the Generating Facility and delivered to the Storage Facility (including pursuant to a Charging Notice), as measured at the Storage Facility Metering Point by the Storage Facility Meter, as such meter readings are adjusted by the CAISO for any applicable Electrical Losses or Station Use. All Charging Energy shall be 6 used solely to charge the Storage Facility, and all Charging Energy shall be generated solely by the Generating Facility.
“Charging Notice” means the operating instruction, and any subsequent updates, given by Buyer’s SC or the CAISO to Seller, directing the Storage Facility to charge at a specific MW rate for a specified period of time or amount of MWh; provided, (a) any such operating instruction shall be in accordance with the Operating Restrictions, and (b) if, during a period when the Storage Facility is instructed by Buyer’s SC or the CAISO to be charging, the actual power output level of the Generating Facility is less than the power level set forth in an applicable “Charging Notice”, such “Charging Notice” shall be deemed to be automatically adjusted to be equal to the actual power level of the Generating Facility. Any Buyer Dispatched Test shall be considered a Charging Notice, and any Charging Notice shall not constitute a Buyer Bid Curtailment, Buyer Curtailment Order or Curtailment Order.
“COD Certificate” has the meaning set forth in Exhibit B. “Collateral Assignment Agreement” has the meaning set forth in Section 14.2. “Commercial Operation” has the meaning set forth in Exhibit B. “Commercial Operation Date” means the date Commercial Operation is achieved. “Commercial Operation Delay Damages” means an amount equal to (a) the Development Security amount required hereunder, divided by (b) “Commercial Operation Storage Capacity Test” means the Storage Capacity Test conducted in connection with Commercial Operation of the Storage Facility, including any additional Storage Capacity Test for additional Storage Facility capacity installed after the Commercial Operation Date pursuant to Section 5 of Exhibit B. “Communications Protocols” means certain Operating Restrictions developed by the Parties pursuant to Exhibit Q that involve procedures and protocols regarding communication with respect to the operation of the Storage Facility pursuant to this Agreement. “Compliance Actions” has the meaning set forth in Section 3.12(a). “Compliance Expenditure Cap” has the meaning set forth in Section 3.12. “Confidential Information” has the meaning set forth in Section 18.1. “Construction Start” has the meaning set forth in Exhibit B. “Construction Start Date” has the meaning set forth in Exhibit B. “Contract Price” has the meaning set forth on the Cover Sheet. For clarity, the Contract Price is each of the Renewable Rate and the Storage Rate. “Contract Term” has the meaning set forth in Section 2.1. 7 “Contract Year” means a period of twelve (12) consecutive months. The first Contract Year shall commence on the Commercial Operation Date and each subsequent Contract Year shall commence on the anniversary of the Commercial Operation Date. “Costs” means, with respect to the Non-Defaulting Party, brokerage fees, commissions and other similar third-party transaction costs and expenses reasonably incurred by such Party either in terminating any arrangement pursuant to which it has hedged or financed its obligations or entering into new arrangements which replace the Agreement; and all reasonable attorneys’ fees and expenses incurred by the Non-Defaulting Party in connection with terminating the Agreement. “Cover Sheet” means the cover sheet to this Agreement, which is incorporated into this Agreement.
“COVID-19” means the epidemic disease designated COVID-19 and the related virus designated SARS-CoV-2 and any mutations thereof, and the efforts of a Governmental Authority to combat such disease.
“CPUC” means the California Public Utilities Commission, or successor entity. “Credit Notice” has the meaning set forth in Section 8.10. “Credit Rating” means, with respect to any entity, the rating then assigned to such entity’s unsecured, senior long-term debt obligations (not supported by third party credit enhancements) or if such entity does not have a rating for its senior unsecured long-term debt, then the rating then assigned to such entity as an issuer rating by S&P, Fitch, or Moody’s. If ratings by S&P, Fitch, and Moody’s are not equivalent, the lower rating shall apply. “Cure Plan” has the meaning set forth in Section 11.1(b)(iii). “Curtailment Order” means any of the following:
(a) CAISO orders, directs, alerts, or provides notice to a Party, including a CAISO Operating Order, to curtail deliveries of Facility Energy for the following reasons: (i) any System Emergency, (ii) any warning of an anticipated System Emergency, or warning of an imminent condition or situation, which jeopardizes CAISO’s electric system integrity or the integrity of other systems to which CAISO is connected, or (iii) in response to an Energy oversupply or potential Energy oversupply, and Buyer or the SC for the Facility submitted a Self-Schedule for the MWhs curtailed corresponding to the MWhs in the VER forecast for the Generating Facility during the relevant time period;
(b) a curtailment ordered by the Transmission Provider for reasons including, but not limited to, (i) any situation that affects normal function of the electric system including, but not limited to, any abnormal condition that requires action to prevent circumstances such as equipment damage, loss of load, or abnormal voltage conditions, or (ii) any warning, forecast or anticipation of conditions or situations that jeopardize the Transmission Provider’s electric system integrity or the integrity of other systems to which the Transmission Provider is connected; 8 (c) a curtailment ordered by CAISO or the Transmission Provider due to a Transmission System Outage; or
(d) a curtailment in accordance with Seller’s obligations under its Interconnection Agreement with the Transmission Provider or distribution operator.

To the extent permitted by CAISO, Buyer shall use commercially reasonable efforts to deliver Charging Energy to the Storage Facility during such Curtailment Order. “Curtailment Period” means the period of time, as measured using current Settlement Intervals, during which Seller reduces generation from the Generating Facility pursuant to a Curtailment Order; provided that the Curtailment Period shall be inclusive of the time required for the Facility to ramp down and ramp up.
“Cycles” means, at any point in time during any Contract Year, the number of equivalent charge/discharge cycles of the Storage Facility, which shall be deemed to be equal to (a) the total cumulative amount of Discharging Energy from the Storage Facility at such point in time during such Contract Year (expressed in MWh) divided by (b) four (4) times the weighted average Effective Storage Capacity for such Contract Year to date. “Daily Delay Damages” means an amount equal to (a) the Development Security amount required hereunder, divided by (b)
“Damage Payment” means the amount to be paid by the Defaulting Party to the Non-Defaulting Party after a Terminated Transaction occurring prior to the Commercial Operation Date, in a dollar amount as set forth in Section 11.3(a). “Day-Ahead Forecast” has the meaning set forth in Section 4.3(c). “Day-Ahead Market” has the meaning set forth in the CAISO Tariff. “Day-Ahead Schedule” has the meaning set forth in the CAISO Tariff. “Deemed Delivered Energy” means the amount of PV Energy expressed in MWh that the Generating Facility would have produced and delivered to the Generating Facility Meter, but that is not produced by the Generating Facility during a Buyer Curtailment Period, which amount shall be equal to the Real-Time Forecast (of the hourly expected PV Energy produced by the Generating Facility) provided pursuant to Section 4.3(d) for the period of time during the Buyer Curtailment Period (or other relevant period), less the amount of PV Energy delivered to the Storage Facility, or to the Delivery Point directly from the Generating Facility, during the Buyer Curtailment Period (or other relevant period); provided that, if the applicable difference is negative, the Deemed Delivered Energy shall be zero (0). If the LMP for the Facility’s PNode during any Settlement Interval was less than zero, Deemed Delivered Energy shall be reduced in such Settlement Interval by the amount of any Charging Energy that was not able to be delivered to the Storage Facility during such Settlement Interval due to the unavailability of the Storage Facility due to a Forced Facility Outage.
“Defaulting Party” has the meaning set forth in Section 11.1(a). 9 “Deficient Month” has the meaning set forth in Section 4.10(e). “Delay Damages” means Daily Delay Damages and Commercial Operation Delay Damages.
“Delivery Point” has the meaning set forth in Exhibit A. “Delivery Term” shall mean the period of Contract Years set forth on the Cover Sheet beginning on the Commercial Operation Date, unless terminated earlier in accordance with the terms and conditions of this Agreement.
“Development Cure Period” has the meaning set forth in Exhibit B. “Development Security” means (a) cash or (b) a Letter of Credit in the amount set forth on the Cover Sheet.
“Discharging Energy” means all Energy delivered to the Delivery Point from the Storage Facility, as measured at the Storage Facility Metering Point by the Storage Facility Meter, as such meter readings are adjusted by the CAISO for any applicable Electrical Losses or Station Use. All Discharging Energy will have originally been delivered to the Storage Facility as Charging Energy. “Discharging Notice” means the operating instruction, and any subsequent updates, given by Buyer’s SC or the CAISO to Seller, directing the Storage Facility to discharge Discharging Energy at a specific MW rate for a specified period of time or to an amount of MWh; provided, (a) any such operating instruction or updates shall be in accordance with the Operating Restrictions, and (b) if, during a period when the Storage Facility is instructed by Buyer’s SC or the CAISO to be discharging, the sum of PV Energy and Discharging Energy would exceed the Interconnection Capacity Limit, such “Discharging Notice” shall be deemed to be automatically adjusted to reduce the amount of Discharging Energy so that the sum of Discharging Energy and PV Energy does not exceed the Interconnection Capacity Limit, until such time as Buyer’s SC or the CAISO issues a further modified Discharging Notice. Any Discharging Notice shall not constitute a Buyer Bid Curtailment, Buyer Curtailment Order or Curtailment Order. “Disclosing Party” has the meaning set forth in Section 18.2. “Early Termination Date” has the meaning set forth in Section 11.2(a). “Effective Date” has the meaning set forth on the Preamble. “Effective FCDS Date” means the date identified in Seller’s Notice to Buyer (along with a Full Capacity Deliverability Status Finding from CAISO) as the date that the Storage Facility has attained Full Capacity Deliverability Status.
“Effective Storage Capacity” means the lesser of (a) PMAX, and (b) the maximum dependable operating capacity of the Storage Facility to discharge Energy for four (4) hours of continuous discharge, as measured in MW AC at the Delivery Point (i.e., measured at the Storage 10 Facility Meter and adjusted for Electrical Losses to the Delivery Point) pursuant to the most recent Storage Capacity Test (including the Commercial Operation Storage Capacity Test), as evidenced by a certificate substantially in the form attached as Exhibit I-2 hereto, in either case (a) or (b) up to but not in excess of (i) the Guaranteed Storage Capacity (with respect to a Commercial Operation Storage Capacity Test) or (ii) the Installed Storage Capacity (with respect to any other Storage Capacity Test).
“Efficiency Rate” means the rate of converting Energy In into Energy Out, as calculated by dividing Energy Out in the applicable month of the Delivery Term by Energy In in the same month of the Delivery Term, expressed as a percentage.
“Electrical Losses” means all transmission or transformation losses (a) between the Generating Facility Metering Point and the Delivery Point associated with delivery of PV Energy, (b) between the Storage Facility Metering Point and the Delivery Point associated with delivery of Discharging Energy, and (c) between the Delivery Point and/or Generating Facility and the Storage Facility Metering Point, as applicable, associated with delivery of Charging Energy to the Storage Facility.
“Eligible Intermittent Resource Protocol” or “EIRP” has the meaning set forth in the CAISO Tariff or a successor CAISO program for intermittent resources. “Eligible Renewable Energy Resource” has the meaning set forth in California Public Utilities Code Section 399.12(e) and California Public Resources Code Section 25741(a), as either code provision is amended or supplemented from time to time. “Energy” means electrical energy, measured in kilowatt-hours or multiple units thereof.

Energy shall include without limitation, reactive power and any other electrical energy products that may be developed or evolve from time to time during the Contract Term. “Energy In” means all Energy delivered into the Storage Facility (not including Energy metered into the Storage Facility when not subject to a Charging Notice) measured at the Storage Facility Metering Point by the Storage Facility Meter.
“Energy Management System” or “EMS” means the Facility’s energy management system.
“Energy Out” means all Energy output from the Storage Facility as measured at the Storage Facility Metering Point by the Storage Facility Meter. “Event of Default” has the meaning set forth in Section 11.1. “Excess MWh” has the meaning set forth in Exhibit C.
“Expected Commercial Operation Date” has the meaning set forth on the Cover Sheet. “Expected Construction Start Date” has the meaning set forth on the Cover Sheet. 11 “Expected Energy” means the quantity of PV Energy that Seller expects to be able to deliver to Buyer from the Generating Facility during each Contract Year, which for each Contract Year is the quantity specified on the Cover Sheet, which amount shall be adjusted proportionately to the reduction from Guaranteed PV Capacity to Installed PV Capacity pursuant to Section 5(a) of Exhibit B, if applicable.
“Facility” means the combined Generating Facility and the Storage Facility. “Facility Energy” means the sum of PV Energy and Discharging Energy, as applicable, during any Settlement Interval or Settlement Period, as measured by the Storage Facility Meter and/or Storage Facility Meter, as applicable, as such meter readings are adjusted by the CAISO for any applicable Electrical Losses or Station Use.
“FERC” means the Federal Energy Regulatory Commission or any successor government agency.
“Fitch” means Fitch Ratings Ltd., or its successor.
“Force Majeure Event” has the meaning set forth in Section 10.1. “Forced Facility Outage” means an unexpected failure of one or more components of the Facility that prevents Seller from generating Energy or making Facility Energy available at the Delivery Point and that is not the result of a Force Majeure Event. “Forecasted Product” has the meaning set forth in Section 4.3(b). “Forecasting Penalty” has the meaning set forth in Section 4.3(f). “Forward Certificate Transfers” has the meaning set forth in Section 4.10(a). “Full Capacity Deliverability Status” or “FCDS” has the meaning set forth in the CAISO Tariff.
“Full Capacity Deliverability Status Finding” means a written confirmation from the CAISO that the Storage Facility is eligible for Full Capacity Deliverability Status. “Future Environmental Attributes” means any and all Green Attributes that become recognized under applicable Law after the Effective Date (and not before the Effective Date), notwithstanding the last sentence of the definition of “Green Attributes” herein. Future Environmental Attributes do not include Tax Credits associated with the construction or operation of the Facility, or other financial incentives in the form of credits, reductions, or allowances associated with the Facility that are applicable to a state or federal income taxation obligation. “Gains” means, with respect to any Party, an amount equal to the present value of the economic benefit to it, if any (exclusive of Costs), resulting from the termination of this Agreement for the remaining Contract Term, determined in a commercially reasonable manner. Factors used in determining the economic benefit to a Party may include, without limitation, reference to information supplied by one or more third parties, which shall exclude Affiliates of the Non- 12 Defaulting Party, including without limitation, quotations (either firm or indicative) of relevant rates, prices, yields, yield curves, volatilities, spreads or other relevant market data in the relevant markets, comparable transactions, forward price curves based on economic analysis of the relevant markets, settlement prices for comparable transactions at liquid trading hubs (e.g., SP-15), all of which should be calculated for the remaining Contract Term, and include the value of Green Attributes and Capacity Attributes.
“Generating Facility” means the solar photovoltaic generating facility described on the Cover Sheet and in Exhibit A, located at the Site and including mechanical equipment and associated facilities and equipment required to deliver (a) PV Energy to the Delivery Point, and (b) Charging Energy to the Storage Facility; provided, that the “Generating Facility” does not include the Storage Facility or the Shared Facilities.
“Generating Facility Meter” means the CAISO approved revenue quality meter or meters (with a 0.3 accuracy class), along with a compatible data processing gateway or remote intelligence gateway, telemetering equipment and data acquisition services sufficient for monitoring, recording and reporting, in real time, the amount of PV Energy delivered to the Generating Facility Metering Point for the purpose of invoicing in accordance with Section 8.1. For clarity, the Generating Facility may contain multiple measurement devices that will make up the Generating Facility Meter, and, unless otherwise indicated, references to the Generating Facility Meter shall mean all such measurement devices and the aggregated data of all such measurement devices, taken together.
“Generating Facility Metering Point” means the location(s) of the Generating Facility Meter(s) shown in Exhibit R.
“Governmental Authority” means any federal, state, provincial, local or municipal government, any political subdivision thereof or any other governmental, congressional or parliamentary, regulatory, or judicial instrumentality, authority, body, agency, department, bureau, or entity with authority to bind a Party at law, including CAISO; provided, “Governmental Authority” shall not in any event include any Party.
“Green Attributes” means any and all credits, benefits, emissions reductions, offsets, and allowances, howsoever entitled (including under the RPS regulations and/or under any and all other international, federal, regional, state or other law, rule, regulation, bylaw, treaty or other intergovernmental compact, decision, administrative decision, program (including any voluntary compliance or membership program), competitive market or business method (including all credits, certificates, benefits, and emission measurements, reductions, offsets and allowances related thereto)), attributable to the generation from the Facility and its displacement of conventional energy generation. Green Attributes include but are not limited to Renewable Energy Credits, as well as: (1) any avoided emissions of pollutants to the air, soil or water such as sulfur oxides (SOx), nitrogen oxides (NOx), carbon monoxide (CO) and other pollutants; (2) any avoided emissions of carbon dioxide (CO2), methane (CH4), nitrous oxide, hydrofluorocarbons, perfluorocarbons, sulfur hexafluoride and other greenhouse gases (GHGs) that have been determined by the United Nations Intergovernmental Panel on Climate Change, or otherwise by law, to contribute to the actual or potential threat of altering the Earth’s climate by trapping heat in the atmosphere; (3) the reporting rights to such avoided emissions, such as Green Tag Reporting 13 Rights. Green Attributes do not include (i) any energy, capacity, reliability or other power attributes from the Facility, (ii) Tax Credits associated with the construction or operation of the Facility and other financial incentives in the form of credits, reductions, or allowances associated with the Facility that are applicable to a state or federal income taxation obligation, or (iii) emission reduction credits encumbered or used by the Facility for compliance with local, state, or federal operating and/or air quality permits. Green Attributes under the preceding definition are limited to Green Attributes that exist under applicable Law as of the Effective Date. “Green Tag Reporting Rights” means the right of a purchaser of renewable energy to report ownership of accumulated “green tags” in compliance with and to the extent permitted by applicable Law and include, without limitation, rights under Section 1605(b) of the Energy Policy Act of 1992, and any present or future federal, state or local certification program or emissions trading program, including pursuant to the WREGIS Operating Rules. “Green Tags” means a unit accumulated on a MWh basis where one (1) represents the Green Attributes associated with one (1) MWh of PV Energy. “Green-e Certified” means the Green Attributes provided to Buyer pursuant to this Agreement are certified under the Green-e Energy National Standard by Buyer after delivery by Seller of such Green Attributes to Buyer.
“Green-e Energy National Standard” means the Green-e Renewable Energy Standard for Canada and the United States (formerly Green-e Energy National Standard) version 3.4, updated November 12, 2019, as may be further amended from time to time. “Guaranteed Capacity” means the sum of (x) the Guaranteed PV Capacity and (y) the Guaranteed Storage Capacity.
“Guaranteed Commercial Operation Date” has the meaning set forth on the Cover Sheet, subject to extension pursuant to Exhibit B.
“Guaranteed Construction Start Date” has the meaning set forth on the Cover Sheet, subject to extension pursuant to Exhibit B.
“Guaranteed Efficiency Rate” means the minimum guaranteed Efficiency Rate of the Storage Facility throughout the Delivery Term, as set forth on the Cover Sheet. “Guaranteed Energy Production” has the meaning set forth in Section 4.7. “Guaranteed PV Capacity” means the generating capacity of the Generating Facility, as measured in MW AC at the Delivery Point (i.e., measured at the Generating Facility Meter and adjusted for Electrical Losses to the Delivery Point), that Seller commits to install pursuant to this Agreement as set forth on the Cover Sheet.
“Guaranteed Storage Availability” has the meaning set forth in Section 4.8. “Guaranteed Storage Capacity” means the maximum dependable operating capability of the Storage Facility to discharge Energy, as measured in MW AC at the Delivery Point (i.e., 14 measured at the Storage Facility Meter and adjusted for Electrical Losses to the Delivery Point) for four (4) hours of continuous discharge, that Seller commits to install pursuant to this Agreement as set forth on the Cover Sheet.
“Guarantor” means, with respect to Seller, any Person that (a) , (b) has a Credit Rating of
from S&P or Fitch, or a Credit Rating of Baa3 or better from Moody’s, (c) is incorporated or organized in a jurisdiction of the United States and is in good standing in such jurisdiction, and (d) executes and delivers a Guaranty for the benefit of Buyer. “Guaranty” means a guaranty from a Guarantor provided for the benefit of Buyer substantially in the form attached as Exhibit L, or as reasonably acceptable to Buyer. “Imbalance Energy” means the amount of Energy in MWh, in any given Settlement Period or Settlement Interval, by which the amount of PV Energy, Charging Energy or Discharging Energy deviates from the amount of Scheduled Energy.
“Indemnified Party” has the meaning set forth in Section 16.1. “Indemnifying Party” has the meaning set forth in Section 16.1. “Initial Synchronization” means the initial delivery of Energy from the Facility to the Delivery Point.
“Installed Capacity” means the sum of (x) the Installed PV Capacity and (y) the Installed Storage Capacity.
“Installed PV Capacity” means the actual generating capacity of the Generating Facility, as measured in MW AC at the Delivery Point, that achieves Commercial Operation, as evidenced by a certificate substantially in the form attached as Exhibit I-1 hereto. “Installed Storage Capacity” means the lesser of (a) PMAX, and (b) maximum dependable operating capacity of the Storage Facility to discharge Energy for four (4) hours of continuous discharge, as measured in MW AC at the Storage Facility Meter Point by the Storage Facility Meter and adjusted for Electrical Losses to the Delivery Point, that achieves Commercial Operation, as evidenced by a certificate substantially in the form attached as Exhibit I-1 hereto, as such capacity may be adjusted pursuant to Section 5 of Exhibit B. “Inter-SC Trade” or “IST” has the meaning set forth in the CAISO Tariff. “Interconnection Agreement” means the interconnection agreement entered into by Seller pursuant to which the Facility will be interconnected with the Transmission System, and pursuant to which Seller’s Interconnection Facilities and any other Interconnection Facilities will be constructed, operated and maintained during the Contract Term. “Interconnection Capacity Limit” means the maximum instantaneous amount of Energy that is permitted to be delivered to the Delivery Point in the amount of 90 MW. 15 “Interconnection Facilities” means the interconnection facilities, control and protective devices and metering facilities required to connect the Facility with the Transmission System in accordance with the Interconnection Agreement.
“Interest Rate” has the meaning set forth in Section 8.2. “Interim Deliverability Status” has the meaning set forth in the CAISO Tariff. “ITC” means the investment tax credit established pursuant to Section 48 of the United States Internal Revenue Code of 1986.
“Joint Powers Act” means the Joint Exercise of Powers Act of the State of California (Government Code Section 6500 et seq.).
“Joint Powers Agreement” means that certain Joint Powers Agreement dated June 27, 2017, as amended from time to time, under which Buyer is organized as a Joint Powers Authority in accordance with the Joint Powers Act.
“kWh” means a kilowatt-hour measured in alternating current, unless expressly stated in terms of direct current.
“Law” means any applicable law, statute, rule, regulation, decision, writ, order, decree or judgment, permit or any interpretation thereof, promulgated or issued by a Governmental Authority.
“Lender” means, collectively, any Person (a) providing senior or subordinated construction, interim, back leverage or long-term debt, equity or tax equity financing or refinancing for or in connection with the development, construction, purchase, installation or operation of the Facility, whether that financing or refinancing takes the form of private debt (including back-leverage debt), equity (including tax equity), public debt or any other form (including financing or refinancing provided to a member or other direct or indirect owner of Seller), including any equity or tax equity investor directly or indirectly providing financing or refinancing for the Facility or purchasing equity ownership interests of Seller and/or its Affiliates, and any trustee or agent or similar representative acting on their behalf, (b) providing interest rate or commodity protection under an agreement hedging or otherwise mitigating the cost of any of the foregoing obligations and/or (c) participating in a lease financing (including a sale leaseback or leveraged leasing structure) with respect to the Facility. “Letter(s) of Credit” means one or more irrevocable, standby letters of credit issued by a U.S. commercial bank or a foreign bank with a U.S. branch with such bank having a Credit Rating of at least A- S&P or A3 from Moody’s, in a form substantially similar to the letter of credit set forth in Exhibit K.
“Licensed Professional Engineer” means an independent, professional engineer selected by Seller and reasonably acceptable to Buyer, licensed in the State of California. “Local Capacity Area Resource” has the meaning set forth in the CAISO Tariff. 16 “Local RAR” means the local Resource Adequacy Requirements established for load-serving entities by the CAISO pursuant to the CAISO Tariff, the CPUC pursuant to the Resource Adequacy Rulings, or by any other Governmental Authority. “Local RAR” may also be known as local area reliability, local resource adequacy, local resource adequacy procurement requirements, or local capacity requirement in other regulatory proceedings or legislative actions. “Locational Marginal Price” or “LMP” has the meaning set forth in the CAISO Tariff. “Losses” means, with respect to any Party, an amount equal to the present value of the economic loss to it, if any (exclusive of Costs), resulting from termination of this Agreement for the remaining Contract Term, determined in a commercially reasonable manner. Factors used in determining economic loss to a Party may include, without limitation, reference to information supplied by one or more third parties, which shall exclude Affiliates of the Non-Defaulting Party, including without limitation, quotations (either firm or indicative) of relevant rates, prices, yields, yield curves, volatilities, spreads or other relevant market data in the relevant markets, comparable transactions, forward price curves based on economic analysis of the relevant markets, settlement prices for comparable transactions at liquid trading hubs (e.g., SP-15), all of which should be calculated for the remaining Contract Term and must include the value of Green Attributes, Capacity Attributes, and Renewable Energy Incentives.
“Lost Output” has the meaning set forth in Section 4.7. “Milestones” means the development activities for significant permitting, interconnection, financing and construction milestones set forth on the Cover Sheet. “Monthly Capacity Payment” means the payment required to be made by Buyer to Seller each month of the Delivery Term as compensation for the provision of Effective Storage Capacity and Capacity Attributes associated with the Storage Facility, as calculated in accordance with Exhibit C.
“Monthly Forecast” has the meaning set forth in Section 4.3(b). “Moody’s” means Moody’s Investors Service, Inc., or its successor. “MW” means megawatts in alternating current, unless expressly stated in terms of direct current.
“MWh” means megawatt-hour measured in alternating current, unless expressly stated in terms of direct current.
“NEER” means NextEra Energy Resources, LLC.
“Negative LMP” means, in any Settlement Period or Settlement Interval, the LMP at the Facility’s PNode is less than zero dollars ($0).
“NERC” means the North American Electric Reliability Corporation. “Net Qualifying Capacity” has the meaning set forth in the CAISO Tariff. 17 “Network Upgrades” has the meaning set forth in the CAISO Tariff. “Non-Defaulting Party” has the meaning set forth in Section 11.2. “Notice” shall, unless otherwise specified in the Agreement, mean written communications by a Party to be delivered by hand delivery, United States mail, overnight courier service, or electronic messaging (e-mail).
“Operating Restrictions” means those rules, requirements, and procedures set forth in Exhibit Q.
“Party” has the meaning set forth in the Preamble.
“Performance Measurement Period” means each two (2) consecutive Contract Years commencing with the first Contract Year so that the first Performance Measurement Period shall include Contract Years 1 and 2. Performance Measurement Periods shall overlap, so that if the first Performance Measurement Period is comprised of Contract Years 1 and 2, the second Performance Measurement Period shall be comprised of Contract Years 2 and 3, the third Performance Measurement Period shall be comprised of Contract Years 3 and 4, and so on; provided, a new Performance Measurement Period shall begin following any Performance Measurement Period for which Seller pays any liquidated damages or provides any Replacement Product under Section 4.7. Thus, for example, if Seller pays any liquidated damages or provides any Replacement Product under Section 4.7 for the Performance Measurement Period that is comprised of Contract Years 4 and 5, the next Performance Measurement Period shall be comprised of Contract Years 6 and 7.
“Performance Security” means (a) cash, (b) a Letter of Credit or (c) a Guaranty in the amount set forth on the Cover Sheet.
“Permitted Transfer” means any of the following:
(a) transactions among Affiliates of Seller, including any corporate reorganization, merger, combination or similar transaction or transfer of assets or ownership interests involving Seller or any of its Affiliates; provided, that (i) Ultimate Parent retains the authority, directly or indirectly, to control such Party, or (ii) a wholly-owned, indirect subsidiary of Ultimate Parent operates the Facility;
(b) (i) the direct or indirect transfer of shares of, or equity interests in, Seller to a Lender, (ii) any exercise by a Lender of its rights and remedies under the Financing Documents, and (iii) any change of economic and voting rights triggered in Seller’s organization documents arising from the financing of the Facility which does not result in the transfer of ownership, economic or voting rights in any entity that had no such rights immediately prior to the change; (c) a Change of Control of Ultimate Parent;
(d) the direct or indirect transfer of shares of, or equity interests in, Seller to a Person; provided, following the transfer (i) an Affiliate of NEER continues to hold an economic interest 18 in the Facility, (ii) the entity that operates the Facility is, or contracts with, a Permitted Transferee, and (iii) Seller, or such Person, maintains the applicable performance assurance requirements; or (f) a transfer of the Facility to a Person pursuant to any of the following (i) all or substantially all of the assets of Ultimate Parent, (ii) all or substantially all of Ultimate Parent’s renewable energy generation portfolio, or (iii) all or substantially all of Ultimate Parent’s solar generation portfolio; provided, that in the case of each of (i), (ii) and (iii), following such transfer the entity that operates the Facility is, or contracts with, a Permitted Transferee and Seller, or such Person, maintains the applicable performance assurance requirements. “Permitted Transferee” means (a) any Affiliate of Seller or (b) any entity that satisfies, or is controlled by another Person that satisfies the following requirements:
(a) A tangible net worth of not less than
or a Credit Rating of at least BBB- from S&P, BBB- from Fitch, or Baa3 from Moody’s; and
(b) At least two (2) years of experience in the ownership and operations of power generation and energy storage facilities similar to the Facility or has retained a third-party with such experience to operate the Facility.
“Person” means any individual, sole proprietorship, corporation, limited liability company, limited or general partnership, joint venture, association, joint-stock company, trust, incorporated organization, institution, public benefit corporation, unincorporated organization, government entity or other entity.
“Planned Outage” means a period during which the Facility is either in whole or in part not capable of providing service due to planned maintenance that has been scheduled in advance in accordance with Section 4.6(a).
“PMAX” means the applicable CAISO-certified maximum operating level of the Storage Facility.
“PMIN” means the applicable CAISO-certified minimum operating level of the Storage Facility.
“PNode” has the meaning set forth in the CAISO Tariff.
“Portfolio” means the single portfolio of electrical energy generating, energy storage, or other assets and entities, including the Facility (or the interests of Seller or Seller’s Affiliates or the interests of their respective direct or indirect parent companies), that is pledged as collateral security in connection with a Portfolio Financing.
“Portfolio Content Category 1” or “PCC1” means any Renewable Energy Credit associated with the generation of electricity from an Eligible Renewable Energy Resource consisting of the portfolio content set forth in California Public Utilities Code Section 399.16(b)(1), as may be amended from time to time or as further defined or supplemented by Law.
19 “Portfolio Financing” means any tax equity or debt transaction entered into by an Affiliate of Seller that is secured only by a Portfolio.
“Portfolio Financing Entity” means any Affiliate of Seller that incurs debt in connection with any Portfolio Financing.
“Product” has the meaning set forth on the Cover Sheet. “Progress Report” means a progress report including the items set forth in Exhibit E. “Prudent Operating Practice” means (a) the applicable practices, methods and acts required by or consistent with applicable Laws and reliability criteria, and otherwise engaged in or approved by a significant portion of the electric utility industry during the relevant time period with respect to grid-interconnected, utility-scale generating facilities with integrated energy storage in the Western United States, or (b) any of the practices, methods and acts which, in the exercise of reasonable judgment in light of the facts known at the time the decision was made, could have been expected to accomplish the desired result at a reasonable cost consistent with good business practices, reliability, safety and expedition. Prudent Operating Practice is not intended to be limited to the optimum practice, method or act to the exclusion of all others, but rather to acceptable practices, methods or acts generally accepted in the industry with respect to grid-interconnected, utility-scale generating facilities with integrated energy storage in the Western United States. Prudent Operating Practice shall include compliance with applicable Laws, applicable reliability criteria, and the applicable criteria, rules and standards promulgated in the National Electric Safety Code and the National Electrical Code, as they may be amended or superseded from time to time, including the criteria, rules and standards of any successor organizations.
“PV Capacity Damages” has the meaning set forth in Section 5 of Exhibit B. “PV Energy” means all Energy delivered from the Generating Facility to the Generating Facility Metering Point and measured by the Generating Facility Meter, as such meter readings are adjusted by the CAISO for any applicable Electrical Losses or Station Use. “Qualifying Capacity” has the meaning set forth in the CAISO Tariff. “RA Compliance Showing” means the (a) Local RAR compliance or advisory showings (or similar or successor showings), (b) RAR compliance or advisory showings (or similar or successor showings), and (c) Flexible RAR compliance or advisory showings (or similar successor showings), in each case, an entity is required to make to the CAISO pursuant to the CAISO Tariff, to the CPUC (and, to the extent authorized by the CPUC, to the CAISO) pursuant to the Resource Adequacy Rulings, or to any Governmental Authority.
“RA Deficiency Amount” means the liquidated damages payment that Seller shall pay to Buyer for an applicable RA Shortfall Month as calculated in accordance with Section Error! Reference source not found.(b).
20 “RA Guarantee Date” means the date set forth in the deliverability Section of the Cover Sheet which is the date the Storage Facility is expected to achieve Full Capacity Deliverability Status.
“RA Shortfall Month” means, for purposes of calculating an RA Deficiency Amount under Section Error! Reference source not found.(b), any month, commencing on the RA Guarantee Date, during which the Net Qualifying Capacity of the Storage Facility for such month was less than the Qualifying Capacity of the Storage Facility for such month (including any month during the period between the RA Guarantee Date and the Effective FCDS Date, if applicable). “Real-Time Forecast” has the meaning set forth in Section 4.3(d). “Real-Time Market” has the meaning set forth in the CAISO Tariff. “Real-Time Price” means the Resource-Specific Settlement Interval LMP as defined in the CAISO Tariff. If there is more than one applicable Real-Time Price for the same period of time, Real-Time Price shall mean the price associated with the smallest time interval. “Receiving Party” has the meaning set forth in Section 18.2. “Reliability Network Upgrades” has the meaning set forth in the CAISO Tariff. “Remedial Action Plan” has the meaning set forth in Section 2.4. “Renewable Energy Credit” has the meaning set forth in California Public Utilities Code Section 399.12(h), as may be amended from time to time or as further defined or supplemented by Law.
“Renewable Energy Incentives” means: (a) all federal, state, or local Tax credits or other Tax benefits associated with the construction, ownership, or production of electricity from the Facility (including credits under Sections 38, 45, 46 and 48 of the Internal Revenue Code of 1986, as amended); (b) any federal, state, or local grants, subsidies or other like benefits relating in any way to the Facility, including a cash grant available under Section 1603 of Division B of the American Recovery and Reinvestment Act of 2009, in lieu of federal Tax credits or any similar or substitute payment available under subsequently enacted federal legislation; and (c) any other form of incentive relating in any way to the Facility that is not a Green Attribute or a Future Environmental Attribute.
“Renewable Rate” has the meaning set forth on the Cover Sheet. “Replacement Energy” has the meaning set forth in Exhibit G. “Replacement Green Attributes” has the meaning set forth in Exhibit G. “Replacement Product” has the meaning set forth in Exhibit G. “Replacement RA” means Resource Adequacy Benefits, if any, equivalent to those that would have been provided by the Facility with respect to the applicable month in which a RA 21 Deficiency Amount is due to Buyer, and located within SP 15 TAC Area and, to the extent that the Facility would have qualified as a Local Capacity Area Resource for such month, described as a Local Capacity Area Resource.
“Requested Confidential Information” has the meaning set forth in Section 18.2. “Resource Adequacy Benefits” means the rights and privileges attached to the Facility that satisfy any entity’s resource adequacy obligations, as those obligations are set forth in any Resource Adequacy Rulings and shall include any local, zonal or otherwise locational attributes associated with the Facility.
“Resource Adequacy Requirements” or “RAR” means the resource adequacy requirements applicable to an entity as established by the CAISO pursuant to the CAISO Tariff, by the CPUC pursuant to the Resource Adequacy Rulings, or by any other Governmental Authority.
“Resource Adequacy Resource” shall have the meaning used in Resource Adequacy Rulings.
“Resource Adequacy Rulings” means CPUC Decisions 04-01-050, 04-10-035, 05-10-042, 06-04-040, 06-06-064, 06-07-031 06-07-031, 07-06-029, 08-06-031, 09-06-028, 10-06-036, 11-06-022, 12-06-025, 13-06-024 and any other existing or subsequent ruling or decision, or any other resource adequacy laws, rules or regulations enacted, adopted or promulgated by any applicable Governmental Authority, however described, as such decisions, rulings, Laws, rules or regulations may be amended or modified from time-to-time throughout the Contract Term.
“S&P” means the Standard & Poor’s Financial Services, LLC (a subsidiary of S&P Global Inc.) or its successor.
“Schedule” has the meaning set forth in the CAISO Tariff, and “Scheduled” has a corollary meaning.
“Scheduled Energy” means the PV Energy, Charging Energy or Discharging Energy that clears under the applicable CAISO market based on the final Day-Ahead Schedule, FMM Schedule (as defined in the CAISO Tariff), and/or any other financially binding Schedule, market instruction or dispatch for the Facility for a given period of time implemented in accordance with the CAISO Tariff.
“Scheduling Coordinator” or “SC” means an entity certified by the CAISO as qualifying as a Scheduling Coordinator pursuant to the CAISO Tariff for the purposes of undertaking the functions specified in “Responsibilities of a Scheduling Coordinator,” of the CAISO Tariff, as amended from time to time.
“Security Interest” has the meaning set forth in Section 8.9. “Self-Schedule” has the meaning set forth in the CAISO Tariff. 22 “Seller” has the meaning set forth on the Cover Sheet. “Seller Initiated Test” has the meaning set forth in Section 4.9(c). “Seller’s WREGIS Account” has the meaning set forth in Section 4.10(a). “Settlement Amount” means the Non-Defaulting Party’s Costs and Losses, on the one hand, netted against its Gains, on the other. If the Non-Defaulting Party’s Costs and Losses exceed its Gains, then the Settlement Amount shall be an amount owing to the Non-Defaulting Party. If the Non-Defaulting Party’s Gains exceed its Costs and Losses, then the Settlement Amount shall be zero dollars ($0). The Settlement Amount does not include consequential, incidental, punitive, exemplary or indirect or business interruption damages. “Settlement Interval” has the meaning set forth in the CAISO Tariff. “Settlement Period” has the meaning set forth in the CAISO Tariff. “Shared Facilities” means the gen-tie lines, transformers, substations, or other equipment, permits, contract rights, and other assets and property (real or personal), in each case, as necessary to enable delivery of Energy from the Facility (which is excluded from Shared Facilities) to the point of interconnection, including the Interconnection Agreement itself, that are used in common with third parties.
“Showing Month” shall be the calendar month of the Delivery Term that is the subject of the RA Compliance Showing, as set forth in the Resource Adequacy Rulings and outlined in the CAISO Tariff. For illustrative purposes only, pursuant to the CAISO Tariff and Resource Adequacy Rulings in effect as of the Effective Date, the monthly RA Compliance Showing made in June is for the Showing Month of August.
“Site” means the real property on which the Facility is or will be located, as further described in Exhibit A, and as shall be updated by Seller at the time Seller provides an executed Construction Start Date certificate in the form of Exhibit J to Buyer; provided, that any such update to the Site that includes real property that was not originally contained within the Site boundaries described in Exhibit A shall be subject to Buyer’s approval of such updates in its sole discretion. “SOC” or “State of Charge” means the (a) level of charge of the Storage Facility relative to (b) the Effective Storage Capacity multiplied by four (4) hours, expressed as a percentage. “SP-15” means the Existing Zone Generation Trading Hub for Existing Zone region SP-15 as set forth in the CAISO Tariff. “Station Use” means the Energy produced or discharged by the Facility (and not otherwise included in the Efficiency Rate) that is used within the Facility to power the information technology, telecommunications, lights, motors, facility control systems and other electrical loads that are necessary for operation of the Facility.
“Storage Capability” has the meaning in Exhibit P.
23 “Storage Capacity Availability Payment True-Up” has the meaning set forth in Exhibit C.
“Storage Capacity Availability Payment True-Up Amount” has the meaning set forth in Exhibit C.
“Storage Capacity Damages” has the meaning set forth in Section 5 of Exhibit B. “Storage Capacity Test” means any test or retest of the Storage Facility to establish the Installed Storage Capacity and/or Effective Storage Capacity, conducted in accordance with the testing procedures, requirements and protocols set forth in Section 4.9 and Exhibit O. “Storage Cure Plan” has the meaning set forth in Section 11.1(b)(iv). “Storage Facility” means the energy storage facility described on the Cover Sheet and in Exhibit A (including the operational requirements of the energy storage facility), located at the Site and including mechanical equipment and associated facilities and equipment required to deliver Storage Product (but excluding any Shared Facilities), and as such storage facility may be expanded or otherwise modified from time to time in accordance with the terms hereof. “Storage Facility Meter” means the CAISO approved bi-directional revenue quality meter or meters (with a 0.3 accuracy class), along with a compatible data processing gateway or remote intelligence gateway, telemetering equipment and data acquisition services sufficient for monitoring, recording and reporting, in real time, the amount of Charging Energy delivered to the Storage Facility Metering Point and the amount of Discharging Energy discharged from the Storage Facility at the Storage Facility Metering Point to the Delivery Point for the purpose of invoicing in accordance with Section 8.1. For clarity, the Facility may contain multiple measurement devices that will make up the Storage Facility Meter, and, unless otherwise indicated, references to the Storage Facility Meter shall mean all such measurement devices and the aggregated data of all such measurement devices, taken together. “Storage Facility Metering Point” means the location(s) of the Storage Facility Meter shown in Exhibit R.
“Storage Product” means (a) Discharging Energy, (b) Capacity Attributes, if any, (c) Effective Storage Capacity, and (d) Ancillary Services, if any, in each case arising from or relating to the Storage Facility.
“Storage Rate” has the meaning set forth on the Cover Sheet. “Stored Energy Level” means, at a particular time, the amount of Energy in the Storage Facility available to be discharged to the Delivery Point as Discharging Energy, expressed in MWh.
“Supplementary Capacity Test Protocol” has the meaning set forth in Exhibit O. “System Emergency” means any condition that requires, as determined and declared by CAISO or the Transmission Provider, automatic or immediate action to (a) prevent or limit harm 24 to or loss of life or property, (b) prevent loss of transmission facilities or generation supply in the immediate vicinity of the Facility, or (c) to preserve Transmission System reliability. “Tax” or “Taxes” means all U.S. federal, state and local and any foreign taxes, levies, assessments, surcharges, duties and other fees and charges of any nature imposed by a Governmental Authority, whether currently in effect or adopted during the Contract Term, including ad valorem, excise, franchise, gross receipts, import/export, license, property, sales and use, stamp, transfer, payroll, unemployment, income, and any and all items of withholding, deficiency, penalty, additions, interest or assessment related thereto. “Tax Credits” means the ITC and any other state, local and/or federal production tax credit, depreciation benefit, tax deduction and/or investment tax credit specific to the production of renewable energy and/or investments in renewable energy facilities or battery storage facilities. “Terminated Transaction” has the meaning set forth in Section 11.2(a). “Termination Payment” has the meaning set forth in Section 11.3(b). “Test Energy” means PV Energy delivered (a) commencing on the later of (a) the first date that the CAISO informs Seller in writing that Seller may deliver Energy to the CAISO and (b) the first date that the Transmission Provider informs Seller in writing that Seller has conditional or temporary permission to operate in parallel with the CAISO Grid, and (b) ending upon the occurrence of the Commercial Operation Date.
“Test Energy Rate” has the meaning set forth in Section 3.6. “Total YTD Calculation Intervals” has the meaning set forth in Exhibit P. “Transmission Provider” means any entity that owns, operates and maintains transmission or distribution lines and associated facilities and/or has entitlements to use certain transmission or distribution lines and associated facilities for the purpose of transmitting or transporting the Facility Energy from the Delivery Point. “Transmission System” means the transmission facilities operated by the CAISO, now or hereafter in existence, which provide energy transmission service downstream from the Delivery Point.
“Transmission System Outage” means an outage on the Transmission System, other than a System Emergency, that is not caused by Seller’s actions or inactions and that prevents Buyer or the CAISO (as applicable) from receiving Facility Energy onto the Transmission System. “Ultimate Parent” means NextEra Energy, Inc., a Delaware corporation. “Unavailable Calculation Interval” has the meaning set forth in Exhibit P. “Variable Energy Resource” or “VER” has the meaning set forth in the CAISO Tariff. 25 “WREGIS” means the Western Renewable Energy Generation Information System or any successor renewable energy tracking program.
“WREGIS Certificate Deficit” has the meaning set forth in Section 4.10(e). “WREGIS Certificates” has the same meaning as “Certificate” as defined by WREGIS in the WREGIS Operating Rules and are designated as eligible for complying with the California Renewables Portfolio Standard.
“WREGIS Operating Rules” means those operating rules and requirements adopted by WREGIS as of May 1, 2018, as subsequently amended, supplemented or replaced (in whole or in part) from time to time.

1.2 Rules of Interpretation.

In this Agreement, except as expressly stated otherwise or unless the context otherwise requires:
(a) headings and the rendering of text in bold and italics are for convenience and reference purposes only and do not affect the meaning or interpretation of this Agreement; (b) words importing the singular include the plural and vice versa and the masculine, feminine and neuter genders include all genders; (c) the words “hereof”, “herein”, and “hereunder” and words of similar import shall refer to this Agreement as a whole and not to any particular provision of this Agreement; (d) a reference to an Article, Section, paragraph, clause, Party, or Exhibit is a reference to that Article, Section, paragraph, clause of, or that Party or Exhibit to, this Agreement unless otherwise specified;
(e) a reference to a document or agreement, including this Agreement shall mean such document, agreement or this Agreement including any amendment or supplement to, or replacement, novation or modification of this Agreement, but disregarding any amendment, supplement, replacement, novation or modification made in breach of such document, agreement or this Agreement;
(f) a reference to a Person includes that Person’s successors and permitted assigns;
(g) the terms “include” and “including” mean “include or including (as applicable) without limitation” and any list of examples following such term shall in no way restrict or limit the generality of the word or provision in respect of which such examples are provided;
(h) references to any statute, code or statutory provision are to be construed as a reference to the same as it may have been, or may from time to time be, amended, modified or 26 reenacted, and include references to all bylaws, instruments, orders and regulations for the time being made thereunder or deriving validity therefrom unless the context otherwise requires; (i) in the event of a conflict, a mathematical formula or other precise description of a concept or a term shall prevail over words providing a more general description of a concept or a term;
(j) references to any amount of money shall mean a reference to the amount in United States Dollars;
(k) the expression “and/or” when used as a conjunction shall connote “any or all of”;
(l) words, phrases or expressions not otherwise defined herein that (i) have a generally accepted meaning in Prudent Operating Practice shall have such meaning in this Agreement or (ii) do not have well known and generally accepted meaning in Prudent Operating Practice but that have well known and generally accepted technical or trade meanings, shall have such recognized meanings; and
(m) each Party acknowledges that it was represented by counsel in connection with this Agreement and that it or its counsel reviewed this Agreement and that any rule of construction to the effect that ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this Agreement.

ARTICLE 2
TERM; CONDITIONS PRECEDENT

2.1 Contract Term.
(a) The term of this Agreement shall commence on the Effective Date and shall remain in full force and effect until the conclusion of the Delivery Term, subject to any early termination provisions set forth herein (“Contract Term”); provided, subject to Buyer’s obligations in Section 3.6, Buyer’s obligations to pay for or accept any Product are subject to Seller’s completion of the conditions precedent pursuant to Section 2.2. (b) Applicable provisions of this Agreement shall continue in effect after termination, including early termination, to the extent necessary to enforce or complete the duties, obligations or responsibilities of the Parties arising prior to termination. The confidentiality obligations of the Parties under Article 18 shall remain in full force and effect for two (2) years following the termination of this Agreement, and all indemnity and audit rights shall remain in full force and effect for one (1) year following the termination of this Agreement.

2.2 Conditions Precedent.

Seller shall provide Notice of expected Commercial Operation to Buyer no less than sixty (60) days in advance of such date. The Delivery Term shall not commence until Seller completes to Buyer’s reasonable satisfaction each of the following conditions:
27 (a) Seller shall have delivered to Buyer (i) a completion certificate from a Licensed Professional Engineer substantially in the form of Exhibit H and (ii) a certificate from a Licensed Professional Engineer substantially in the form of Exhibit I-1 setting forth the Installed PV Capacity, the Installed Storage Capacity and the Installed Capacity on the Commercial Operation Date;
(b) A Participating Generator Agreement and a Meter Service Agreement between Seller and CAISO shall have been executed and delivered and be in full force and effect, and a copy of each such agreement delivered to Buyer;
(c) An Interconnection Agreement between Seller and the Transmission Provider shall have been executed and delivered and be in full force and effect and a copy of the Interconnection Agreement delivered to Buyer;
(d) All applicable regulatory authorizations, approvals and permits for the operation of the Facility that are capable of being satisfied on the Commercial Operation Date have been obtained and all conditions thereof have been satisfied and shall be in full force and effect; (e) Seller has obtained CAISO Certification for the Facility; (g) Seller has received CEC Precertification of the Facility (and reasonably expects to receive final CEC Certification and Verification for the Facility in no more than one hundred eighty (180) days from the Commercial Operation Date); (h) Seller (with the reasonable participation of Buyer) shall have completed all applicable WREGIS registration requirements, including the completion and submittal of all applicable registration forms and supporting documentation, which may include applicable interconnection agreements, informational surveys related to the Facility, QRE service agreements, and other appropriate documentation required to effect Facility registration with WREGIS and to enable Renewable Energy Credit transfers related to the Facility within the WREGIS system;
(i) Seller has delivered the Performance Security to Buyer in accordance with Section 8.8; and
(j) Seller has paid Buyer for all amounts owing under this Agreement, if any, including Delay Damages.

2.3 Development; Construction; Progress Reports.

Within fifteen (15) days after the close of (i) each calendar quarter following the Effective Date until the Construction Start Date and (ii) each calendar month from the first calendar month following the Construction Start Date and continuing through the Commercial Operation Date, Seller shall provide to Buyer a Progress Report and agree to regularly scheduled meetings between representatives of Buyer and Seller to review such reports and discuss Seller’s construction progress. The form of the Progress Report is set forth in Exhibit E. Seller shall also provide Buyer with any reasonably requested documentation (subject to confidentiality restrictions) directly related to the achievement of Milestones within ten (10) Business Days of receipt of such request 28 by Seller. Seller is solely responsible for the design and construction of the Facility, including the location of the Site, the Facility layout, and the selection and procurement of the equipment comprising the Facility.

2.4 Remedial Action Plan.

If Seller misses a Milestone by more than thirty (30) days, except as the result of Force Majeure Event or Buyer Default, Seller shall submit to Buyer, within ten (10) Business Days of the end of such thirty (30)-day period following the Milestone completion date, a remedial action plan (“Remedial Action Plan”), which will describe in detail any delays (actual or anticipated) beyond the scheduled Milestone dates, including the cause of the delay (e.g., governmental approvals, financing, property acquisition, design activities, equipment procurement, project construction, interconnection, or any other factor), Seller’s detailed description of its proposed course of action to achieve the missed Milestones and all subsequent Milestones by the Guaranteed Commercial Operation Date; provided, delivery of any Remedial Action Plan shall not relieve Seller of its obligation to provide Remedial Action Plans with respect to any subsequent Milestones and to achieve the Guaranteed Commercial Operation Date in accordance with the terms of this Agreement. Subject to the provisions of Exhibit B, so long as Seller complies with its obligations under this Section 2.4, Seller shall not be considered in default of its obligations under this Agreement solely as a result of missing any Milestone.

ARTICLE 3

PURCHASE AND SALE

3.1 Purchase and Sale of Product.

Subject to the terms and conditions of this Agreement, during the Delivery Term, Buyer shall purchase all the Product produced by or associated with the Facility at the Contract Price and in accordance with Exhibit C, and Seller shall supply and deliver to Buyer all the Product produced by or associated with the Facility. At its sole discretion, Buyer may during the Delivery Term re-sell or use for another purpose all or a portion of the Product, provided that no such re-sale or use shall relieve Buyer of any obligations hereunder. During the Delivery Term, Buyer shall have exclusive rights to offer, bid, or otherwise submit the Product, and/or any component thereof, from the Facility after the Delivery Point for resale in the market, and retain and receive any and all related revenues.

3.2 Sale of Green Attributes.

During the Delivery Term, Seller shall sell and deliver to Buyer, and Buyer shall purchase from Seller, all Green Attributes attributable to the PV Energy generated by the Facility. Upon request of Buyer, Seller shall use commercially reasonable efforts to (a) submit, and receive approval from the Center for Resource Solutions (or any successor that administers the Green-e Certification process), for the Green-e tracking attestations and (b) support Buyer’s efforts to qualify the Green Attributes transferred by Seller as Green-e Certified.

3.3 Imbalance Energy.
29 Buyer and Seller recognize that in any given Settlement Period the amount of PV Energy and/or Discharging Energy delivered from the Generating Facility and/or the Storage Facility may deviate from the amounts thereof scheduled with the CAISO. To the extent there are such deviations, any costs or revenues from such imbalances shall be solely for the account of Buyer.

3.4 Ownership of Renewable Energy Incentives.

Seller shall have all right, title and interest in and to all Renewable Energy Incentives.

Buyer acknowledges that any Renewable Energy Incentives belong to Seller. If any Renewable Energy Incentives, or values representing the same, are initially credited or paid to Buyer, Buyer shall cause such Renewable Energy Incentives or values relating to same to be assigned or transferred to Seller without delay. Buyer shall reasonably cooperate with Seller, at Seller’s sole expense, in Seller’s efforts to meet the requirements for any certification, registration, or reporting program relating to Renewable Energy Incentives.

3.5 Future Environmental Attributes.
(a) The Parties acknowledge and agree that as of the Effective Date, environmental attributes sold under this Agreement are restricted to Green Attributes; however, Future Environmental Attributes may be created by a Governmental Authority through Laws enacted after the Effective Date. Subject to the final sentence of this Section 3.5(a) and Section

3.5(b), in such event, Buyer shall bear all costs associated with the transfer, qualification, verification, registration and ongoing compliance for such Future Environmental Attributes, but there shall be no increase in the Contract Price. Upon Seller’s receipt of Notice from Buyer of Buyer’s intent to claim such Future Environmental Attributes, the Parties shall determine the necessary actions and additional costs associated with such Future Environmental Attributes.

Seller shall have no obligation to alter the Facility or the operation of the Facility unless the Parties have agreed on all necessary terms and conditions relating to such alteration or change in operation and Buyer has agreed to reimburse Seller for all costs, losses, and liabilities associated with such alteration or change in operation.
(b) If Buyer elects to receive Future Environmental Attributes pursuant to Section 3.5(a), the Parties agree to negotiate in good faith with respect to the development of further agreements and documentation necessary to effectuate the transfer of such Future Environmental Attributes, including agreement with respect to (i) appropriate transfer, delivery and risk of loss mechanisms, and (ii) appropriate allocation of any additional costs to Buyer, as set forth above; provided, that the Parties acknowledge and agree that such terms are not intended to alter the other material terms of this Agreement.

3.6 Test Energy.

No less than thirty (30) days prior to the first day on which Test Energy is expected to be available from the Facility, Seller shall notify Buyer of the availability of the Test Energy. If and to the extent the Facility generates Test Energy, Seller shall sell and Buyer shall purchase from Seller all Test Energy and any associated Products on an as-available basis for up to days from the first delivery of Test Energy. As compensation for such Test Energy and associated Product, Buyer shall pay Seller an amount equal to of the Renewable 30 Rate (the “Test Energy Rate”). The conditions precedent in Section 2.2 are not applicable to the Parties’ obligations under this Section 3.6.

3.7 Capacity Attributes.

Seller shall request Full Capacity Deliverability Status in the CAISO generator interconnection process for the Storage Facility. As between Buyer and Seller, Seller shall be responsible for the cost and installation of any Network Upgrades associated with obtaining such Full Capacity Deliverability Status.
(a) Throughout the Delivery Term and subject to Section 3.12, Seller grants, pledges, assigns and otherwise commits to Buyer all the Capacity Attributes from the Facility. (b) Throughout the Delivery Term and subject to Section 3.12, Seller shall use commercially reasonable efforts to maintain eligibility for Full Capacity Deliverability Status for the Storage Facility from the CAISO and shall perform all actions necessary to ensure that the Facility qualifies to provide Resource Adequacy Benefits to Buyer. Throughout the Delivery Term, and subject to Section 3.12, Seller hereby covenants and agrees to transfer all Resource Adequacy Benefits from the Facility to Buyer.
(c) For the duration of the Delivery Term, and subject to Section 3.12, Seller shall take all commercially reasonable actions, including complying with all applicable registration and reporting requirements, and execute all documents or instruments necessary to enable Buyer to use all of the Capacity Attributes committed by Seller to Buyer pursuant to this Agreement.

3.8 Resource Adequacy Failure.
(a) RA Deficiency Determination. For each RA Shortfall Month Seller shall pay to Buyer the RA Deficiency Amount as liquidated damages and/or provide Replacement RA, as set forth in Section 3.8(b), as the sole remedy for the Capacity Attributes that Seller failed to convey to Buyer.
(b) RA Deficiency Amount Calculation. For each RA Shortfall Month, Seller shall pay to Buyer an amount (the “RA Deficiency Amount”) equal to provided that Seller may, as an
alternative to paying some or all of the RA Deficiency Amounts, provide Replacement RA in the 31 amount of (X) the Qualifying Capacity of the Storage Facility with respect to such month, minus (Y) the Net Qualifying Capacity of the Storage Facility with respect to such month, provided that any Replacement RA capacity is communicated by Seller to Buyer with Replacement RA product information in a written Notice substantially in the form of Exhibit M at least seventy-five (75) days before the applicable Showing Month for the purpose of monthly RA reporting.

3.9 CEC Certification and Verification.

Subject to Section 3.12 and in accordance with the timing set forth in this Section 3.9, Seller shall take all necessary steps including, but not limited to, making or supporting timely filings with the CEC to obtain and maintain CEC Certification and Verification for the Facility throughout the Delivery Term, including compliance with all applicable requirements for certified facilities set forth in the current version of the RPS Eligibility Guidebook (or its successor). Seller shall obtain CEC Precertification by the Commercial Operation Date. Within thirty (30) days after the Commercial Operation Date, Seller shall apply with the CEC for final CEC Certification and Verification. Within one hundred eighty (180) days after the Commercial Operation Date, Seller shall obtain and maintain throughout the remainder of the Delivery Term the final CEC Certification and Verification. Seller must promptly notify Buyer and the CEC of any changes to the information included in Seller’s application for CEC Certification and Verification for the Facility.

3.10 Eligibility.

Subject to Section 3.12, Seller, and, if applicable, its successors, represents and warrants that throughout the Delivery Term of this Agreement that: (i) the Facility qualifies and is certified by the CEC as an Eligible Renewable Energy Resource as such term is defined in Public Utilities Code Section 399.12 or Section 399.16; and (ii) the Facility’s output delivered to Buyer qualifies under the requirements of the California Renewables Portfolio Standard. To the extent a change in Law occurs after execution of this Agreement that causes this representation and warranty to be materially false or misleading, it shall not be an Event of Default if Seller has used commercially reasonable efforts to comply with such change in Law. The term “commercially reasonable efforts” as used in this Section 3.10 means efforts consistent with and subject to Section 3.12.

3.11 California Renewables Portfolio Standard.

Subject to Section 3.12, Seller shall also take all other actions necessary to ensure that the PV Energy produced from the Generating Facility is tracked for purposes of satisfying the California Renewables Portfolio Standard requirements, as may be amended or supplemented by the CPUC or CEC from time to time.

3.12 Compliance Expenditure Cap.

If a change in Law occurring after the Effective Date has increased Seller’s cost to comply with Seller’s obligations under this Agreement that are made subject to this Section 3.12, including with respect to obtaining, maintaining, conveying or effectuating Buyer’s use of Green Attributes and Capacity Attributes (as applicable), then the Parties agree that the maximum aggregate amount of costs and expenses Seller shall be required to bear during the Delivery Term to comply with all 32 of such obligations shall be capped at of
Guaranteed Capacity (“Compliance Expenditure Cap”).
(a) Any actions required for Seller to comply with its obligations set forth in the first paragraph above, the cost of which will be included in the Compliance Expenditure Cap, shall be referred to collectively as the “Compliance Actions.” (b) If Seller reasonably anticipates the need to incur out-of-pocket expenses in excess of the Compliance Expenditure Cap in order to take any Compliance Action Seller shall provide Notice to Buyer of such anticipated out-of-pocket expenses. (c) Buyer will have sixty (60) days to evaluate such Notice (during which time period Seller is not obligated to take any Compliance Actions described in the Notice) and shall, within such time, either (1) agree to reimburse Seller for all or some portion of the costs that exceed the Compliance Expenditure Cap (such Buyer-agreed upon costs, the “Accepted Compliance Costs”), or (2) waive Seller’s obligation to take such Compliance Actions, or any part thereof for which Buyer has not agreed to reimburse Seller. If Buyer does not respond to a Notice given by Seller under this Section 3.12 within sixty (60) days after Buyer’s receipt of same, Buyer shall be deemed to have waived its rights to require Seller to take the Compliance Actions that are the subject of the Notice, and Seller shall have no further obligation to take, and no liability for any failure to take, such Compliance Actions until such time as Buyer agrees to pay such Accepted Compliance Costs.
(d) If Buyer agrees to reimburse Seller for the Accepted Compliance Costs, then Seller shall take such Compliance Actions covered by the Accepted Compliance Costs as agreed upon by the Parties and Buyer shall reimburse Seller for Seller’s actual costs to effect the Compliance Actions, not to exceed the Accepted Compliance Costs, within sixty (60) days from the time that Buyer receives an invoice and documentation of such costs from Seller.

3.13 Project Configuration.

In order to optimize the benefits of the Facility, Buyer and Seller each agree that if requested by the other Party, then Buyer and Seller will discuss in good faith potential reconfiguration of the Facility or Interconnection Facilities, including the use of grid energy to provide Charging Energy; provided, neither Party shall be obligated to agree to any changes under this Agreement, or to incur any expense in connection with such changes, except under terms mutually acceptable to both Parties as set forth in a written agreement.

ARTICLE 4

OBLIGATIONS AND DELIVERIES

4.1 Delivery.
(a) Energy. Subject to the provisions of this Agreement, commencing on the Commercial Operation Date through the end of the Contract Term, Seller shall supply and deliver the Product to Buyer at the Delivery Point, and Buyer shall take delivery of the Product at the Delivery Point in accordance with the terms of this Agreement. Seller shall be responsible for paying or satisfying when due any costs or charges imposed in connection with the delivery of Facility Energy to the Delivery Point, including any operation and maintenance charges imposed 33 by the Transmission Provider directly relating to the Facility’s operations. Buyer shall be responsible for all costs, charges and penalties, if any, imposed in connection with the delivery of Facility Energy at and after the Delivery Point, including without limitation transmission costs and transmission line losses and imbalance charges. The PV Energy, Charging Energy and Discharging Energy will be scheduled with the CAISO by Buyer (or Buyer’s designated Scheduling Coordinator) in accordance with Exhibit D.
(b) Green Attributes. All Green Attributes associated with Test Energy and the PV Energy during the Delivery Term are exclusively dedicated to and vested in Buyer. Seller represents and warrants that Seller holds the rights to all Green Attributes from the Facility, and Seller agrees to convey and hereby conveys all such Green Attributes to Buyer as included in the delivery of the Product from the Facility.

4.2 Title and Risk of Loss.
(a) Energy. Title to and risk of loss related to the Facility Energy, shall pass and transfer from Seller to Buyer at the Delivery Point. Seller warrants that all Product delivered to Buyer is free and clear of all liens, security interests, claims and encumbrances of any kind. (b) Green Attributes. Title to and risk of loss related to the Green Attributes shall pass and transfer from Seller to Buyer upon the transfer of such Green Attributes in accordance with WREGIS.

4.3 Forecasting.

Seller shall provide the forecasts described below. Seller shall use commercially reasonable efforts to forecast accurately and to transmit such information in a format reasonably acceptable to Buyer (or Buyer’s designee).
(a) Annual Forecast of Energy. No less than forty-five (45) days before (i) the first day of the first Contract Year of the Delivery Term and (ii) the beginning of each calendar year for every subsequent Contract Year during the Delivery Term, Seller shall provide to Buyer and the SC (if applicable) a non-binding forecast of each month’s average-day expected PV Energy, by hour, for the following calendar year in a form substantially similar to the table found in Exhibit F-1, or as reasonably requested by Buyer.
(b) Monthly Forecast of PV Energy and Available Capacity. No less than thirty (30) days before the beginning of Commercial Operation, and thereafter ten (10) Business Days before the beginning of each month during the Delivery Term, Seller shall provide to Buyer and the SC (if applicable) a non-binding forecast of the hourly expected (i) available capacity of the Generating Facility, (ii) PV Energy, (iii) available Effective Storage Capacity, and (iv) available Storage Capability (items (i)-(iv) collectively referred to as the “Forecasted Product”), for each day of the following month in a form substantially similar to Exhibits F-1, F-2, F-3 and F-4, as applicable (“Monthly Forecast”).
(c) Day-Ahead Forecast. By 5:30 AM Pacific Prevailing Time on the Business Day immediately preceding the date of delivery, or as otherwise specified by Buyer consistent with Prudent Operating Practice, Seller shall provide Buyer with a non-binding forecast of the 34 hourly expected Forecasted Product, in each case, for each hour of the immediately succeeding day (“Day-Ahead Forecast”). A Day-Ahead Forecast provided in a day prior to any non-Business Day(s) shall include non-binding forecasts for the immediate day, each succeeding non-Business Day and the next Business Day. Each Day-Ahead Forecast shall clearly identify, for each hour, Seller’s best estimate of the hourly expected Forecasted Product. Such Day-Ahead Forecasts shall be sent to Buyer’s on-duty Scheduling Coordinator. If Seller fails to provide Buyer with a Day-Ahead Forecast as required herein for any period, then for such unscheduled delivery period only Buyer shall rely on any Real-Time Forecast or the Monthly Forecast or Buyer’s best estimate based on information reasonably available to Buyer.
(d) Real-Time Forecasts. During the Delivery Term, Seller shall notify Buyer of any changes from the Day-Ahead Forecast of one (1) MW or more in the hourly expected Forecasted Product (“Real-Time Forecast”), that directly result from a Forced Facility Outage, Force Majeure Event or other cause that has not been communicated or is not reasonably available to Buyer or Buyer’s SC, as soon as reasonably possible, but no later than one (1) hour prior to the deadline for submitting schedules to the CAISO in accordance with the rules for participation in the Real-Time Market. If the Forecasted Product changes by at least one (1) MW as of a time that is less than one (1) hour prior to the Real-Time Market deadline, but before such deadline, then Seller must notify Buyer as soon as reasonably possible. Such Real-Time Forecasts of PV Energy shall be provided by an Approved Forecast Vendor and shall contain information regarding the beginning date and time of the event resulting in the change in any Forecasted Product, as applicable, the expected end date and time of such event, and any other information required by the CAISO or reasonably requested by Buyer. With respect to any Forced Facility Outage, Seller shall use commercially reasonable efforts to notify Buyer of such outage within ten (10) minutes of the commencement of the Forced Facility Outage. Seller shall inform Buyer of any developments that are reasonably likely to affect either the duration of such outage or the availability of the Facility during or after the end of such outage. Such Real-Time Forecasts shall be communicated in a method acceptable to Buyer; provided that Buyer specifies the method no later than sixty (60) days prior to the effective date of such requirement. In the event Buyer fails to provide Notice of an acceptable method for communications under this Section 4.3(d), then Seller shall send such communications by telephone and e-mail to Buyer. (e) Forced Facility Outages. Notwithstanding anything to the contrary herein, Seller shall promptly notify Buyer’s on-duty Scheduling Coordinator of Forced Facility Outages and Seller shall keep Buyer informed of any developments that will affect either the duration of the outage or the availability of the Facility during or after the end of the outage. (f) Forecasting Penalties. In the event Seller does not in a given hour provide the forecast required in Section 4.3(d) and Buyer incurs a loss or penalty resulting from its scheduling activities with respect to Facility Energy during such hour, Seller shall be responsible for a “Forecasting Penalty” for each such hour equal to the product of (A) the absolute difference (if any) between (i) the expected PV Energy for such hour (which, assumes no Charging Energy or Discharging Energy in such hour) set forth in the Monthly Forecast, and (ii) the actual PV Energy (absent any Charging Energy and Discharging Energy), multiplied by (B) the absolute value of the Real-Time Price in such hour. Settlement of Forecasting Penalties shall occur as set forth in Article 8 of this Agreement.
35 (g) CAISO Tariff Requirements. Seller will comply with all applicable obligations for Variable Energy Resources under the CAISO Tariff and the Eligible Intermittent Resource Protocol, including providing appropriate operational data and meteorological data, and will fully cooperate with Buyer, Buyer’s SC, and CAISO, in providing all data, information, and authorizations required thereunder.

4.4 Dispatch Down/Curtailment.
(a) General. Seller agrees to reduce the amount of PV Energy and/or Discharging Energy produced by the Facility, by the amount and for the period set forth in any Curtailment Order, Buyer Curtailment Order, or notice received from CAISO in respect of a Buyer Bid Curtailment; provided, Seller is not required to reduce such amount to the extent it is inconsistent with the limitations of the Facility set out in the Operating Restrictions. (b) Buyer Curtailment. Buyer shall have the right to order Seller to curtail deliveries of PV Energy through Buyer Curtailment Orders, provided that Buyer shall pay Seller for all Deemed Delivered Energy associated with a Buyer Curtailment Period at the Renewable Rate, subject to the limitations of Section (b) of Exhibit C. (c) Failure to Comply. If Seller fails to comply with a Buyer Curtailment Order, Buyer Bid Curtailment or Curtailment Order, then, for each MWh of PV Energy that is delivered by the Generating Facility to the Delivery Point that is in excess of the Buyer Curtailment Order, Buyer Bid Curtailment or Curtailment Order, Seller shall pay Buyer for each such MWh at an amount equal to the sum of (A) + (B) + (C), where: (A) is the amount, if any, paid to Seller by Buyer for delivery of such excess MWh and, (B) is the sum, for all Settlement Intervals with a Negative LMP during the Buyer Curtailment Period or Curtailment Period, of the absolute value of the product of such excess MWh in each Settlement Interval and the Negative LMP for such Settlement Interval, and (C) is any penalties assessed by the CAISO or other charges assessed by the CAISO resulting from Seller’s failure to comply with the Buyer Curtailment Order, Buyer Bid Curtailment or Curtailment Order.
(d) Seller Equipment Required for Curtailment Instruction Communications.

Seller shall acquire, install, and maintain such facilities, communications links and other equipment, and implement such protocols and practices, as necessary to respond to and follow instructions, including an electronic signal conveying real time and intra-day instructions, to operate the Facility as directed by the Buyer in accordance with this Agreement and/or a Governmental Authority, including to implement a Buyer Curtailment Order, Buyer Bid Curtailment or Curtailment Order in accordance with the then-current methodology and used to transmit such instructions. If at any time during the Delivery Term, Seller’s facilities, communications links or other equipment, protocols or practices are not in compliance with the then-current methodologies, Seller shall take the steps necessary to become compliant as soon as commercially reasonably possible. Seller shall be liable pursuant to Section 4.4(c) for failure to comply with a Buyer Curtailment Order, Buyer Bid Curtailment or Curtailment Order, during the time that Seller’s facilities, communications links or other equipment, protocols or practices are not in compliance with applicable methodologies. A Buyer Curtailment Order, Buyer Bid Curtailment or Curtailment Order communication via such systems and facilities shall have the same force and effect on Seller as any other form of communication. 36 4.5 Energy Management.
(a) Charging Generally. Upon receipt of a valid Charging Notice, Seller shall take any and all action necessary to deliver the Charging Energy to the Storage Facility in order to deliver the Storage Product in accordance with the terms of this Agreement, including maintenance, repair or replacement of equipment in Seller’s possession or control used to deliver the Charging Energy from the Generating Facility to the Storage Facility. Except as otherwise expressly set forth in this Agreement, including Section 4.5(c), Section 4.5(i), and Section

4.9(d)(i), Buyer shall be responsible for paying all CAISO costs and charges associated with Charging Energy.
(b) Charging Notices. Buyer will have the right to charge the Storage Facility seven (7) days per week and twenty-four (24) hours per day (including holidays), by causing Charging Notices to be issued, subject to the requirements and limitations set forth in this Agreement, including the Operating Restrictions. Each Charging Notice issued in accordance with this Agreement will be effective unless and until Buyer’s SC or the CAISO modifies such Charging Notice by providing Seller with an updated Charging Notice. (c) No Unauthorized Charging. Seller shall not charge the Storage Facility during the Delivery Term other than pursuant to a valid Charging Notice (it being understood that Seller may adjust a Charging Notice to the extent necessary to maintain compliance with the Operating Restrictions), or in connection with a Seller Initiated Test (including Facility maintenance or a Storage Capacity Test), or pursuant to a notice from the Transmission Provider or Governmental Authority. If, during the Delivery Term, Seller charges the Storage Facility (i) to a Stored Energy Level greater than the Stored Energy Level provided for in a Charging Notice, or (ii) in violation of the first sentence of this Section 4.5(c), then (x) Seller shall pay Buyer the cost of such Energy associated with such charging of the Storage Facility , and (y) Buyer shall be entitled to discharge such Energy and entitled to all of the CAISO revenues and benefits (including Storage Product) associated with such discharge. Notwithstanding the foregoing, during any Curtailment Period, Buyer shall use commercially reasonable efforts to cause all curtailed PV Energy to be used as Charging Energy.
(d) No Unauthorized Discharging. Seller shall not discharge the Storage Facility during the Delivery Term other than pursuant to a valid Discharging Notice (it being understood that Seller may adjust a Discharging Notice to the extent necessary to maintain compliance with the Operating Restrictions), or in connection with a Seller Initiated Test (including Facility maintenance or a Storage Capacity Test), or pursuant to a notice from the Transmission Provider or Governmental Authority. Buyer will have the right to discharge the Storage Facility seven (7) days per week and twenty-four (24) hours per day (including holidays), by causing Discharging Notices to be issued, subject to the requirements and limitations set forth in this Agreement. Each Discharging Notice issued in accordance with this Agreement will be effective unless and until Buyer’s SC or the CAISO modifies such Discharging Notice by providing Seller with an updated Discharging Notice.
(e) Curtailments. Notwithstanding anything in this Agreement to the contrary, during any Settlement Interval, Curtailment Orders, Buyer Curtailment Orders, and Buyer Bid Curtailments applicable to such Settlement Interval shall have priority over any Charging Notices 37 or Discharging Notices applicable to such Settlement Interval, and Seller shall have no liability for violation of this Section 4.5 or any Charging Notice or Discharging Notice if and to the extent such violation is caused by Seller’s compliance with any Curtailment Order, Buyer Curtailment Order, Buyer Bid Curtailment or other instruction or direction from Buyer or its SC or a Governmental Authority or the Transmission Provider. Buyer shall have the right, but not the obligation, to provide Seller with updated Charging Notices and Discharging Notices during any Buyer Curtailment Order, Buyer Bid Curtailment or Curtailment Order consistent with the Operating Restrictions.
(f) Unauthorized Charges and Discharges. If Seller or any third party charges, discharges or otherwise uses the Storage Facility other than as permitted hereunder or as expressly addressed in Section 4.5(g), it shall be a breach by Seller and Seller shall hold Buyer harmless from, and indemnify Buyer against, all actual costs or losses associated therewith, and be responsible to Buyer for any damages arising therefrom and, if Seller fails to implement procedures reasonably acceptable to Buyer to prevent any further occurrences of the same, then the failure to implement such procedures shall be an Event of Default under Article 11. (g) CAISO Dispatches. During the Delivery Term, CAISO Dispatches shall have priority over any Charging Notice or Discharging Notice issued by Buyer’s SC, and Seller shall have no liability for violation of this Section 4.5 or any Charging Notices or Discharging Notice if and to the extent such violation is caused by Seller’s compliance with any CAISO Dispatch. During any time interval during the Delivery Term in which the Storage Facility is capable of responding to a CAISO Dispatch, but the Storage Facility deviates from a CAISO Dispatch, Seller shall be responsible for all CAISO charges and penalties resulting from such deviation (in addition to any Buyer remedy related to overcharging of the Storage Facility as set forth in Section 4.9(c).) To the extent the Storage Facility is unable to respond to ADS signals during any Calculation Interval, then as an exclusive remedy, such Calculation Interval shall be deemed an Unavailable Calculation Interval for purposes of calculating the YTD Annual Storage Capacity Availability.
(h) Pre-Commercial Operation Date Period, etc. Prior to the Commercial Operation Date, Buyer shall have no rights to issue or cause to be issued Charging Notices or Discharging Notices, and Seller shall have exclusive rights to charge and discharge the Storage Facility; provided, prior to the Commercial Operation Date Seller shall only charge and discharge the Storage Facility in connection with installation, commissioning and testing of the Storage Facility.
(i) Station Use. Notwithstanding anything to the contrary in this Agreement, the Parties acknowledge (i) Seller is responsible for providing all Energy to serve Station Use (including paying the cost of any Energy from the grid to serve Station Use), (ii) the supply of such Station Use shall not be deemed a deviation for purposes of Section 4.5(k)(i) or a violation of this Agreement, including Sections 4.5(c), (d), and (f), and (iii) Station Use may not be supplied from PV Energy, Charging Energy or Discharging Energy.

4.6 Reduction in Delivery Obligation.
(a) Facility Maintenance.
38 (i) Seller shall provide to Buyer written schedules for Planned Outages for each of the Generating Facility and Storage Facility for each Contract Year no later than thirty (30) days prior to the first day of the applicable Contract Year. Buyer may provide comments on the proposed Planned Outage schedule no later than ten (10) days after receiving any such schedule, and Seller shall in good faith take into account any such comments. Seller shall deliver to Buyer the final updated schedule of Planned Outages no later than ten (10) days after receiving Buyer’s comments. Seller shall be permitted to reduce deliveries of Product during any period of such Planned Outages.
(ii) If reasonably required in accordance with Prudent Operating Practices, Seller may perform maintenance at a different time than maintenance scheduled pursuant to Section 4.6(a)(i). Seller shall provide Notice to Buyer within the time period determined by the CAISO for the Facility, as a Resource Adequacy Resource that is subject to the Availability Standards, to qualify for an “Approved Maintenance Outage” under the CAISO Tariff (or such shorter period as may be reasonably acceptable to Buyer based on the likelihood of dispatch by Buyer), and Seller shall limit maintenance repairs performed pursuant to this Section

4.6(a) to periods when Buyer does not reasonably believe the Facility will be dispatched. (iii) Notwithstanding anything in this Agreement to the contrary, no Planned Outages of the Generating Facility or Storage Facility shall be scheduled or planned from each June 1 through September 30 during the Delivery Term, unless approved by Buyer in writing in its sole discretion. In the event that Seller has a previously Planned Outage that becomes coincident with a System Emergency, Seller shall make all reasonable efforts to reschedule such Planned Outage.
(b) Forced Facility Outage. Seller shall be permitted to reduce deliveries of Product during any Forced Facility Outage. Seller shall provide Buyer with Notice and expected duration (if known) of any Forced Facility Outage.
(c) System Emergencies and other Interconnection Events. Seller shall be permitted to reduce deliveries of Product during any period of System Emergency, Transmission System Outage, Buyer Curtailment Period or upon notice of a Curtailment Order pursuant to the terms of this Agreement, the Interconnection Agreement or applicable tariff. (d) Force Majeure Event. Seller shall be permitted to reduce deliveries of Product during any Force Majeure Event, so long as Seller complies with the applicable requirements of Article 10.
(e) Health and Safety. Seller shall be permitted to reduce deliveries of Product as necessary to maintain health and safety pursuant to Section 6.2.

Notwithstanding anything in this Section 4.6 to the contrary, any such reductions in Product deliveries shall not excuse (i) the Storage Facility’s unavailability for purposes of calculating the Annual Storage Capacity Availability, or (ii) in the case of Sections 4.6(a), (b) and (e), Seller’s obligation to deliver Capacity Attributes.

4.7 Guaranteed Energy Production.
39 During each Performance Measurement Period during the Delivery Term, Seller shall deliver to Buyer an amount of PV Energy, not including any Excess MWh, equal to no less than the Guaranteed Energy Production (as defined below). “Guaranteed Energy Production” means an amount of PV Energy, as measured in MWh, equal to
constituting such Performance
Measurement Period. Seller shall be excused from achieving the Guaranteed Energy Production during any Performance Measurement Period only to the extent of any Buyer Event of Default or other Buyer failure to perform that directly prevents Seller from being able to deliver PV Energy to the Delivery Point. For purposes of determining whether Seller has achieved the Guaranteed Energy Production, Seller shall be deemed to have delivered to Buyer the sum of (a) any Deemed Delivered Energy, plus (b) PV Energy in the amount it could reasonably have delivered to Buyer but was prevented from delivering to Buyer by reason of any Force Majeure Events, System Emergency, Transmission System Outage, or Curtailment Periods (“Lost Output”). If Seller fails to achieve the Guaranteed Energy Production amount in any Performance Measurement Period, Seller shall pay Buyer damages calculated in accordance with Exhibit G; provided that Seller may, as an alternative, provide Replacement Product (as defined in Exhibit G) delivered to Buyer at SP 15 EZ Gen Hub under a Day-Ahead Schedule as an IST within ninety (90) days after the conclusion of the applicable Performance Measurement Period (i) upon a schedule reasonably acceptable to Buyer, and (ii) provided that such deliveries do not impose additional costs upon Buyer for which Seller refuses to provide reimbursement.

4.8 Storage Facility Availability; Ancillary Services.
(a) During the Delivery Term, the Storage Facility shall maintain an Annual Storage Capacity Availability during each Contract Year of no less than (the “Guaranteed Storage Availability”), which Annual Storage Capacity Availability shall be calculated in accordance with Exhibit P.
(b) During the Delivery Term, the Storage Facility shall maintain an Efficiency Rate of no less than the Guaranteed Efficiency Rate. Buyer’s sole remedy for an Efficiency Rate that is less than the Guaranteed Efficiency Rate is Seller’s payment of liquidated damages pursuant to Section (f) of Exhibit C.
(c) Buyer’s exclusive remedies for Seller’s failure to achieve the Guaranteed Storage Availability are (i) the adjustment of Seller’s payment for the Product by application of the Capacity Availability Factor (as set forth in Exhibit C), and (ii) in the case of a Seller Event of Default as set forth in Section 11.1(b)(iv), the applicable remedies set forth in Article 11. (d) Seller shall operate and maintain the Storage Facility throughout the Delivery Term so as to be able to provide the Ancillary Services in accordance with the specifications set forth in the Operating Restrictions and the Storage Facility’s initial CAISO Certification associated with the Installed Storage Capacity. To the extent the Storage Facility is unable to provide Ancillary Services for any reason not excused hereunder during any Calculation Interval that is not otherwise deemed an Unavailable Calculation Interval, then as exclusive remedies the Storage Capability for such Calculation Interval shall be deemed 40 (e) Upon Buyer’s reasonable request, Seller shall submit the Storage Facility for additional CAISO Certification so that the Storage Facility may provide additional Ancillary Services that the Facility is at the relevant time actually physically capable of providing consistent with the definition of Ancillary Services herein, and subject to the Operating Restrictions, provided that Buyer has agreed to reimburse Seller for any material costs Seller incurs in connection with such additional CAISO Certification.

4.9 Storage Facility Testing.
(a) Storage Capacity Tests. Prior to the Commercial Operation Date, Seller shall schedule and complete a Commercial Operation Storage Capacity Test in accordance with Exhibit O. Thereafter, Seller and Buyer shall have the right to run additional Storage Capacity Tests in accordance with Exhibit O.
(i) Buyer shall have the right to send one or more representative(s) to witness all Storage Capacity Tests.
(ii) Following each Storage Capacity Test, Seller shall submit a testing report in accordance with Exhibit O. If the actual capacity determined pursuant to a Storage Capacity Test varies from the then-current Effective Storage Capacity, then the actual capacity determined pursuant to such Storage Capacity Test shall become the new Effective Storage Capacity at the beginning of the day following the completion of the test for all purposes under this Agreement.
(b) Additional Testing. Seller shall, at times and for durations reasonably agreed to by Buyer, conduct necessary testing to ensure the Storage Facility is functioning properly and the Storage Facility is able to respond to Buyer or CAISO Dispatches. (c) Buyer or Seller Initiated Tests. Any testing of the Storage Facility requested by Buyer after the Commercial Operation Storage Capacity Tests and all required annual tests pursuant to Section B of Exhibit O shall be deemed Buyer-instructed dispatches of the Facility (“Buyer Dispatched Test”). Any test of the Storage Facility that is not a Buyer Dispatched Test (including all tests conducted prior to Commercial Operation, any Commercial Operation Storage Capacity Tests, any Storage Capacity Test conducted if the Effective Storage Capacity immediately prior to such Storage Capacity Test is below of the Installed Storage Capacity, any test required by CAISO (including any test required to obtain or maintain CAISO Certification), and other Seller-requested discretionary tests or dispatches, at times and for durations reasonably agreed to by Buyer, that Seller deems necessary for purposes of reliably operating or maintaining the Storage Facility or for re-performing a required test within a reasonable number of days of the initial required test (considering the circumstances that led to the need for a retest)) shall be deemed a “Seller Initiated Test”. (i) For any Seller Initiated Test, other than Storage Capacity Tests required by Exhibit O for which there is a stated notice requirement, Seller shall notify Buyer no later than twenty-four (24) hours prior thereto (or any shorter period reasonably acceptable to Buyer consistent with Prudent Operating Practices).
41 (ii) No Charging Notices or Discharging Notices shall be issued during any Seller Initiated Test or Buyer Dispatched Test except as reasonably requested by Seller or Buyer to implement the applicable test. Periods during which Buyer Dispatched Tests render the Storage Facility (or any portion thereof, as applicable) unavailable shall be excluded for purposes of calculating the Annual Storage Capacity Availability. The Storage Facility will be deemed unavailable during any Seller Initiated Test, and Buyer shall not dispatch or otherwise schedule the Storage Facility during such Seller Initiated Test. (d) Testing Costs and Revenues.
(i) For all Buyer Dispatched Tests, Buyer shall direct only Charging Energy to be used to charge the Storage Facility and Buyer shall be entitled to all CAISO revenues associated with a Storage Facility dispatch during a Buyer Dispatched Test. For all Seller Initiated Tests, (1) Seller shall reimburse Buyer for all CAISO costs and charges associated with Charging Energy used for such Seller Initiated Test, and (2) Seller shall be entitled to all CAISO revenues associated with the discharge of such Energy, but all Green Attributes associated therewith shall be for Buyer’s account at no additional cost to Buyer. Buyer shall pay to Seller, in the month following Buyer’s receipt of such CAISO revenues and otherwise in accordance with Exhibit C, all applicable CAISO revenues received by Buyer and associated with the discharge Energy associated with such Seller Initiated Test.
(ii) Buyer shall be responsible for all costs, expenses and fees payable or reimbursable to its representative(s) witnessing any Facility test. Any such representative(s) of Buyer shall adhere to the safety and security procedures of Seller, which shall be provided by Seller to Buyer in writing. Buyer shall indemnify and hold Seller harmless for any losses or claims for personal injury, death or property damage to the Facility or Site to the extent caused by Buyer, its authorized agents, employees, and inspectors, during any such access. (iii) Except as set forth in Sections 4.9(d)(i) and (ii), all other costs of any testing of the Storage Facility shall be borne by Seller.

4.10 WREGIS.

Seller shall, at its sole expense, but subject to Section 3.12, take all actions and execute all documents or instruments necessary to ensure that all WREGIS Certificates associated with all Renewable Energy Credits corresponding to all PV Energy are issued and tracked for purposes of satisfying the requirements of the California Renewables Portfolio Standard and transferred in a timely manner to Buyer for Buyer’s sole benefit. Seller shall transfer the Renewable Energy Credits to Buyer. Seller shall comply with all Laws, including the WREGIS Operating Rules, regarding the certification and transfer of such WREGIS Certificates to Buyer and Buyer shall be given sole title to all such WREGIS Certificates. Seller shall be deemed to have satisfied the warranty in Section 4.10(g), provided that Seller fulfills its obligations under Sections 4.10(a) through (g) below. In addition:
(a) Prior to the Commercial Operation Date, Seller shall register the Facility with WREGIS and establish an account with WREGIS (“Seller’s WREGIS Account”), which Seller shall maintain until the end of the Delivery Term. Seller shall transfer the WREGIS 42 Certificates using “Forward Certificate Transfers” (as described in the WREGIS Operating Rules) from Seller’s WREGIS Account to the WREGIS account(s) of Buyer or the account(s) of a designee that Buyer identifies by Notice to Seller (“Buyer’s WREGIS Account”). Seller shall be responsible for all expenses associated with registering the Facility with WREGIS, establishing and maintaining Seller’s WREGIS Account, paying WREGIS Certificate issuance and transfer fees, and transferring WREGIS Certificates from Seller’s WREGIS Account to Buyer’s WREGIS Account.
(b) Seller shall cause Forward Certificate Transfers to occur on a monthly basis in accordance with the certification procedure established by the WREGIS Operating Rules. Since WREGIS Certificates will only be created for whole MWh amounts of PV Energy generated, any fractional MWh amounts (i.e., kWh) will be carried forward until sufficient generation is accumulated for the creation of a WREGIS Certificate.
(c) Seller shall, at its sole expense, ensure that the WREGIS Certificates for a given calendar month correspond with the PV Energy for such calendar month as evidenced by the Facility’s metered data.
(d) Due to the ninety (90) day delay in the creation of WREGIS Certificates relative to the timing of invoice payment under Section 8.2, Buyer shall make an invoice payment for a given month in accordance with Section 8.2 before the WREGIS Certificates for such month are formally transferred to Buyer in accordance with the WREGIS Operating Rules and this Section 4.10. Notwithstanding this delay, Buyer shall have all right and title to all such WREGIS Certificates upon payment to Seller in accordance with Section 8.2. (e) A “WREGIS Certificate Deficit” means any deficit or shortfall in WREGIS Certificates delivered to Buyer for a calendar month as compared to the PV Energy for the same calendar month (“Deficient Month”) caused by an error or omission of Seller. If any WREGIS Certificate Deficit is caused by, or the result of any action or inaction of, Seller, then the amount of PV Energy in the Deficient Month shall be reduced by three (3) times the amount of the WREGIS Certificate Deficit for purposes of calculating Buyer’s payment to Seller under Article 8 and the Guaranteed Energy Production for the applicable Contract Year; provided, such adjustment shall not apply to the extent that Seller either (x) resolves the WREGIS Certificate Deficit within ninety (90) days after the Deficient Month or (y) provides Replacement Green Attributes (as defined in Exhibit G) within ninety (90) days after the Deficient Month (i) upon a schedule reasonably acceptable to Buyer and (ii) provided that such deliveries do not impose additional costs upon Buyer for which Seller refuses to provide reimbursement. Without limiting Seller’s obligations under this Section 4.10, if a WREGIS Certificate Deficit is caused solely by an error or omission of WREGIS, the Parties shall cooperate in good faith to cause WREGIS to correct its error or omission.
(f) If WREGIS changes the WREGIS Operating Rules after the Effective Date or applies the WREGIS Operating Rules in a manner inconsistent with this Section 4.10 after the Effective Date, the Parties promptly shall modify this Section 4.10 as reasonably required to cause and enable Seller to transfer to Buyer’s WREGIS Account a quantity of WREGIS Certificates for each given calendar month that corresponds to the PV Energy in the same calendar month. 43 (g) Seller warrants that all necessary steps to allow the Renewable Energy Credits transferred to Buyer to be tracked in WREGIS will be taken prior to the first Energy delivery under this Agreement.

ARTICLE 5
TAXES

5.1 Allocation of Taxes and Charges.

Seller shall pay or cause to be paid all Taxes on or with respect to the Facility or on or with respect to the sale and making available of Product to Buyer, that are imposed on Product prior to its delivery to Buyer at the time and place contemplated under this Agreement. Buyer shall pay or cause to be paid all Taxes on or with respect to the delivery to and purchase by Buyer of Product that are imposed on Product at and after its delivery to Buyer at the time and place contemplated under this Agreement (other than withholding or other Taxes imposed on Seller’s income, revenue, receipts or employees). If a Party is required to remit or pay Taxes that are the other Party’s responsibility hereunder, such Party shall promptly pay the Taxes due and then seek and receive reimbursement from the other for such Taxes. In the event any sale of Product hereunder is exempt from or not subject to any particular Tax, Buyer shall provide Seller with all necessary documentation to evidence such exemption or exclusion within thirty (30) days after the date Buyer makes such claim. Buyer shall indemnify, defend, and hold Seller harmless from any liability with respect to Taxes for which Buyer is responsible hereunder and from which Buyer claims it is exempt.

5.2 Cooperation.

Each Party shall use reasonable efforts to implement the provisions of and administer this Agreement in accordance with the intent of the Parties to minimize all Taxes, so long as no Party is materially adversely affected by such efforts. The Parties shall cooperate to minimize Tax exposure; provided, neither Party shall be obligated to incur any financial or operational burden to reduce Taxes for which the other Party is responsible hereunder without receiving due compensation therefor from the other Party. All Product delivered by Seller to Buyer hereunder shall be a sale made at wholesale, with Buyer reselling such Product.

ARTICLE 6

MAINTENANCE OF THE FACILITY

6.1 Maintenance of the Facility.

Seller shall, as between Seller and Buyer, be solely responsible for the operation and maintenance of the Facility and the generation and sale of Product and shall comply with Law and Prudent Operating Practice relating to the operation and maintenance of the Facility and the generation and sale of Product.

6.2 Maintenance of Health and Safety.

Seller shall take reasonable safety precautions with respect to the operation, maintenance, repair and replacement of the Facility. If Seller becomes aware of any circumstances relating to 44 the Facility that create an imminent risk of damage or injury to any Person or any Person’s property, Seller shall take prompt, reasonable action to prevent such damage or injury and shall give Buyer’s emergency contact identified in Exhibit N Notice of such condition. Such action may include disconnecting and removing all or a portion of the Facility or suspending the supply of Facility Energy to the Delivery Point.

6.3 Shared Facilities.

The Parties acknowledge and agree that certain of the Shared Facilities and Interconnection Facilities, and Seller’s rights and obligations under the Interconnection Agreement, may be subject to certain shared facilities and/or co-tenancy agreements to be entered into among Seller, the Transmission Provider, Seller’s Affiliates, and/or third parties pursuant to which certain Interconnection Facilities may be subject to joint ownership and shared maintenance and operation arrangements; provided, such agreements (i) shall permit Seller to perform or satisfy, and shall not purport to limit, its obligations hereunder and (ii) provide for separate metering of the Facility.

ARTICLE 7

METERING

7.1 Metering.
(a) Subject to Section 7.1(b) (with respect to the entirety of the following Section 7.1(a)), unless the Parties agree otherwise pursuant to Section 3.13, the Facility shall have a separate CAISO Resource ID for each of the Generating Facility and the Storage Facility. Seller shall measure the amount of PV Energy using the Generating Facility Meter. Seller shall measure the Charging Energy and the Discharging Energy using the Storage Facility Meter. Seller shall separately meter or account for all Station Use. All meters shall be operated pursuant to applicable CAISO-approved calculation methodologies and maintained at Seller’s cost. Subject to meeting any applicable CAISO requirements, the Storage Facility Meter and Generating Facility Meter shall be programmed to adjust for all Electrical Losses from such meters to the Delivery Point in a manner compliance with the CAISO Tariff and subject to Buyer’s prior written approval, not to be unreasonably withheld. Metering shall be consistent with the Metering Diagram set forth as Exhibit R. Each Storage Facility Meter and Generating Facility Meter shall be kept under seal, such seals to be broken only when the meters are to be tested, adjusted, modified or relocated. In the event Seller breaks a seal, Seller shall notify Buyer as soon as practicable. In addition, Seller hereby agrees to provide all meter data to Buyer in a form reasonably acceptable to Buyer, and consents to Buyer obtaining from CAISO the CAISO meter data directly relating to the Facility and all inspection, testing and calibration data and reports. Seller and Buyer, or Buyer’s Scheduling Coordinator, shall cooperate to allow both Parties to retrieve the meter reads from the CAISO Market Results Interface (MRI-S) and/or directly from the CAISO meter(s) at the Facility. (b) Section 7.1(a) is based on the Parties’ mutual understanding as of the Effective Date that (i) the CAISO requires the configuration of the Facility to include, as the sole meters for the Facility, the Generating Facility Meter and the Storage Facility Meter, (ii) the CAISO requires the Generating Facility Meter and the Storage Facility Meter to be programmed for Electrical Losses as set forth in the definition of Electrical Losses in this Agreement, and (iii) the automatic adjustments to Charging Notices and Discharging Notices as set forth in the 45 definitions of Charging Notice and Discharging Notice in this Agreement will not result in Seller violating, or incurring any costs, penalties or charges under, the CAISO Tariff. If any of the foregoing mutual understandings in (i), (ii), or (iii) between the Parties become incorrect during the Delivery Term, the Parties shall cooperate in good faith to make any amendments and modifications to the Facility and this Agreement as are reasonably necessary to conform this Agreement to the CAISO Tariff and avoid, to the maximum extent practicable, any CAISO charges, costs or penalties that may be imposed on either Party due to non-conformance with the CAISO Tariff, such agreement not to be unreasonably delayed, conditioned or withheld.

7.2 Meter Verification.

Annually, if Seller has reason to believe there may be a meter malfunction, or upon Buyer’s reasonable request, Seller shall test the meter. The tests shall be conducted by independent third parties qualified to conduct such tests. Buyer shall be notified seven (7) days in advance of such tests and have a right to be present during such tests. If a meter is inaccurate it shall be promptly repaired or replaced. If a meter is inaccurate by more than one percent (1%) and it is not known when the meter inaccuracy commenced (if such evidence exists such date will be used to adjust prior invoices), then the invoices covering the period of time since the last meter test shall be adjusted for the amount of the inaccuracy on the assumption that the inaccuracy persisted during one-half of such period so long as such adjustments are accepted by CAISO and WREGIS; provided, such period may not exceed twelve (12) months.

ARTICLE 8
INVOICING AND PAYMENT; CREDIT

8.1 Invoicing.

Seller shall use commercially reasonable efforts to deliver an invoice to Buyer for Product no later than the tenth (10th) day of each month for the previous calendar month. Each invoice shall (a) reflect records of metered data, including (i) CAISO metering and transaction data sufficient to document
and verify the amount of Product delivered by the Facility for any Settlement Period during the 2preceding month, including the amount of PV Energy, Charging Energy, Discharging Energy, Energy In, Energy Out, Replacement RA and Replacement Product delivered to Buyer (if any), the calculation of Deemed Delivered Energy and Adjusted Energy Production, the LMP prices at the Delivery Point for each Settlement Period, and the Contract Price applicable to such Product in accordance with Exhibit C, and (ii) data showing a calculation of the Monthly Capacity Payment and other relevant data for the prior month; and (b) be in a format reasonably specified by Buyer, covering the Product provided in the preceding month determined in accordance with the applicable provisions of this Agreement. Buyer shall, and shall cause its Scheduling Coordinator to, provide Seller with all reasonable access (including, in real time, to the maximum extent reasonably possible) to any records, including invoices or settlement data from the CAISO, forecast data and other information, all as may be necessary from time to time for Seller to prepare and verify the accuracy of all invoices.

8.2 Payment.
46 Buyer shall make payment to Seller for Product (and any other amounts due) by wire transfer or ACH payment to the bank account provided on each monthly invoice. Buyer shall pay undisputed invoice amounts by the later of (a) ten (10) Business Days after Buyer’s receipt of the invoice from Seller, and (b) the thirtieth (30th) day of the month after the operational month for which such invoice was rendered; provided, if such due date falls on a weekend or legal holiday, such due date shall be the next Business Day. Payments made after the due date will be considered late and will bear interest on the unpaid balance. If the amount due is not paid on or before the due date or if any other payment that is due and owing from one Party to another is not paid on or before its applicable due date, a late payment charge shall be applied to the unpaid balance and shall be added to the next billing statement. Such late payment charge shall be calculated based on an annual Interest Rate equal to the prime rate published on the date of the invoice in The Wall Street Journal (or, if The Wall Street Journal is not published on that day, the next succeeding date of publication), plus two percent (2%) (the “Interest Rate”). If the due date occurs on a day that is not a Business Day, the late payment charge shall begin to accrue on the next succeeding Business Day.

8.3 Books and Records.

To facilitate payment and verification, each Party shall maintain all books and records necessary for billing and payments, including copies of all invoices under this Agreement, for a period of at least two (2) years or as otherwise required by Law. Upon fifteen (15) days’ Notice to the other Party, either Party shall be granted reasonable access to the accounting books and records within the possession or control of the other Party pertaining to all invoices generated pursuant to this Agreement.

8.4 Payment Adjustments; Billing Errors.

Payment adjustments shall be made if Buyer or Seller discovers there have been good faith inaccuracies in invoicing that are not otherwise disputed under Section 8.5 or an adjustment to an amount previously invoiced or paid is required due to a correction of data by the CAISO, or there is determined to have been a meter inaccuracy sufficient to require a payment adjustment. If the required adjustment is in favor of Buyer, Buyer’s next monthly payment shall be credited in an amount equal to the adjustment. If the required adjustment is in favor of Seller, Seller shall add the adjustment amount to Buyer’s next monthly invoice. Adjustments in favor of either Buyer or Seller shall bear interest, until settled in full, in accordance with Section 8.2, accruing from the date on which the adjusted amount should have been due.

8.5 Billing Disputes.

A Party may, in good faith, dispute the correctness of any invoice or any adjustment to an invoice rendered under this Agreement or adjust any invoice for any arithmetic or computational error within twelve (12) months of the date the invoice, or adjustment to an invoice, was rendered.

In the event an invoice or portion thereof, or any other claim or adjustment arising hereunder, is disputed, payment of the undisputed portion of the invoice shall be required to be made when due.

Any invoice dispute or invoice adjustment shall be in writing and shall state the basis for the dispute or adjustment. Payment of the disputed amount shall not be required until the dispute is resolved. Upon resolution of the dispute, any required payment shall be made within five (5) 47 Business Days of such resolution along with interest accrued at the Interest Rate from and including the original due date to but excluding the date paid. Inadvertent overpayments shall be returned via adjustments in accordance with Section 8.4. Any dispute with respect to an invoice is waived if the other Party is not notified in accordance with this Section 8.5 within twelve (12) months after the invoice is rendered or subsequently adjusted, except to the extent any misinformation was from a third party not affiliated with any Party and such third party corrects its information after the twelve-month period. If an invoice is not rendered within twelve (12) months after the close of the month during which performance occurred, the right to payment for such performance is waived.

8.6 Netting of Payments.

The Parties hereby agree that they shall discharge mutual debts and payment obligations due and owing to each other on the same date through netting, in which case all amounts owed by each Party to the other Party for the purchase and sale of Product during the monthly billing period under this Agreement or otherwise arising out of this Agreement, including any related damages calculated pursuant to Exhibits B and P, interest, and payments or credits, shall be netted so that only the excess amount remaining due shall be paid by the Party who owes it.

8.7 Seller’s Development Security.

To secure its obligations under this Agreement, Seller shall deliver the Development Security to Buyer within ten (10) days after the Effective Date. Seller shall maintain the Development Security in full force and effect; provided that the Development Security shall not be replenishable. Upon the earlier of (a) Seller’s delivery of the Performance Security, or (b) sixty (60) days after termination of this Agreement, Buyer shall return the Development Security to Seller, less the amounts drawn in accordance with this Agreement.

8.8 Seller’s Performance Security.

To secure its obligations under this Agreement, Seller shall deliver Performance Security to Buyer on or before the Commercial Operation Date. If the Performance Security is not in the form of cash or Letter of Credit, it shall be substantially in the form set forth in Exhibit L. Seller shall maintain the Performance Security in full force and effect, and Seller shall within five (5) Business Days after any draw thereon replenish the Performance Security in the event Buyer collects or draws down any portion of the Performance Security for any reason permitted under this Agreement other than to satisfy a Termination Payment, until the following have occurred: (a) the Delivery Term has expired or terminated early; and (b) all payment obligations of Seller due and payable under this Agreement, including compensation for penalties, Termination Payment, indemnification payments or other damages are paid in full (whether directly or indirectly such as through set-off or netting); provided, however, that in no event shall Seller have any obligation to replenish the Performance Security to the extent that the aggregate amount of such replenishment of the Performance Security during the Delivery Term exceeds one (1) times the Performance Security requirement. Following the occurrence of both events, Buyer shall promptly return to Seller the unused portion of the Performance Security.

8.9 First Priority Security Interest in Cash or Cash Equivalent Collateral. 48 To secure its obligations under this Agreement, and until released as provided herein, Seller hereby grants to Buyer a present and continuing first-priority security interest (“Security Interest”) in, and lien on (and right to net against), and assignment of the Development Security, Performance Security, any other cash collateral and cash equivalent collateral posted pursuant to Sections 8.7 and 8.8 and any and all interest thereon or proceeds resulting therefrom or from the liquidation thereof, whether now or hereafter held by, on behalf of, or for the benefit of Buyer, and Seller agrees to take all action as Buyer reasonably requires in order to perfect Buyer’s Security Interest in, and lien on (and right to net against), such collateral and any and all proceeds resulting therefrom or from the liquidation thereof. Upon or any time after the occurrence of an Event of Default caused by Seller, an Early Termination Date resulting from an Event of Default caused by Seller, or an occasion provided for in this Agreement where Buyer is authorized to retain all or a portion of the Development Security or Performance Security, Buyer may do any one or more of the following (in each case subject to the final sentence of this Section 8.9):
(a) Exercise any of its rights and remedies with respect to the Development Security and Performance Security, including any such rights and remedies under Law then in effect;
(b) Draw on any outstanding Letter of Credit issued for its benefit and retain any cash held by Buyer as Development Security or Performance Security; and (c) Liquidate all Development Security or Performance Security (as applicable) then held by or for the benefit of Buyer free from any claim or right of any nature whatsoever of Seller, including any equity or right of purchase or redemption by Seller.

Buyer shall apply the proceeds of the collateral realized upon the exercise of any such rights or remedies to reduce Seller’s obligations under this Agreement (Seller remains liable for any amounts owing to Buyer after such application), subject to Buyer’s obligation to return any surplus proceeds remaining after such obligations are satisfied in full. 49 ARTICLE 9

NOTICES

9.1 Addresses for the Delivery of Notices.
50 Any Notice required, permitted, or contemplated hereunder shall be in writing, shall be addressed to the Party to be notified at the address set forth in Exhibit N or at such other address or addresses as a Party may designate for itself from time to time by Notice hereunder.

9.2 Acceptable Means of Delivering Notice.

Each Notice required, permitted, or contemplated hereunder shall be deemed to have been validly served, given or delivered as follows: (a) if sent by United States mail with proper first class postage prepaid, three (3) Business Days following the date of the postmark on the envelope in which such Notice was deposited in the United States mail; (b) if sent by a regularly scheduled overnight delivery carrier with delivery fees either prepaid or an arrangement with such carrier made for the payment of such fees, the next Business Day after the same is delivered by the sending Party to such carrier; (c) if sent by electronic communication (including electronic mail or other electronic means) at the time indicated by the time stamp upon delivery and, if after 5 pm, on the next Business Day; or (d) if delivered in person, upon receipt by the receiving Party.

Notwithstanding the foregoing, Notices of outages or other scheduling or dispatch information or requests, may be sent by electronic communication and shall be considered delivered upon successful completion of such transmission.

ARTICLE 10

FORCE MAJEURE

10.1 Definition.
(a) “Force Majeure Event” means any act or event that delays or prevents a Party from timely performing all or a portion of its obligations under this Agreement or from complying with all or a portion of the conditions under this Agreement if such act or event, despite the exercise of reasonable efforts, cannot be avoided by and is beyond the reasonable control (whether direct or indirect) of and without the fault or negligence of the Party relying thereon as justification for such delay, nonperformance, or noncompliance. (b) Without limiting the generality of the foregoing, so long as the following events, despite the exercise of reasonable efforts, cannot be avoided by, and are beyond the reasonable control (whether direct or indirect) of and without the fault or negligence of the Party relying thereon as justification for such delay, nonperformance or noncompliance, a Force Majeure Event may include an act of God or the elements, such as flooding, lightning, hurricanes, tornadoes, or ice storms; explosion; fire; volcanic eruption; flood; epidemic; landslide; mudslide; sabotage; terrorism; earthquake; or other cataclysmic events; an act of public enemy; war; blockade; civil insurrection; riot; civil disturbance; or strikes or other labor difficulties caused or suffered by a Party or any third party except as set forth below. (c) Notwithstanding the foregoing, the term “Force Majeure Event” does not include (i) economic conditions or changes in Law that render a Party’s performance of this Agreement at the Contract Price unprofitable or otherwise uneconomic (including an increase in component or compliance costs for any reason, including foreign or domestic tariffs, Buyer’s ability to buy Product at a lower price, or Seller’s ability to sell the Product, or any component thereof, at a higher price, than under this Agreement); (ii) Seller’s inability to obtain permits or approvals of any type for the construction, operation, or maintenance of the Facility, except to the 51 extent such inability is caused by a Force Majeure Event; (iii) the inability of a Party to make payments when due under this Agreement, unless the cause of such inability is an event that would otherwise constitute a Force Majeure Event as described above; (iv) a Curtailment Order, except to the extent such Curtailment Period is caused by a Force Majeure Event; (v) Seller’s inability to obtain sufficient labor, equipment, materials, or other resources to build or operate the Facility, including the lack of wind, sun or other fuel source of an inherently intermittent nature, except to the extent such inability is caused by a Force Majeure Event; (vi) a strike, work stoppage or labor dispute limited only to any one or more of Seller, Seller’s Affiliates, Seller’s contractors, their subcontractors thereof or any other third party employed by Seller to work on the Facility; (vii) any equipment failure, except if such equipment failure is caused by a Force Majeure Event; or (viii) any action or inaction by any third party, including Transmission Provider, that delays or prevents the approval, construction or placement in service of any Interconnection Facilities or Network Upgrades, except to the extent caused by a Force Majeure Event.

10.2 No Liability If a Force Majeure Event Occurs.

Except as provided in Section 4 of Exhibit B, neither Seller nor Buyer shall be liable to the other Party in the event it is prevented from performing its obligations hereunder in whole or in part due to a Force Majeure Event. The Party rendered unable to fulfill any obligation by reason of a Force Majeure Event shall take reasonable actions necessary to remove such inability with due speed and diligence. Nothing herein shall be construed as permitting that Party to continue to fail to perform after said cause has been removed. The obligation to use due speed and diligence shall not be interpreted to require resolution of labor disputes by acceding to demands of the opposition when such course is inadvisable in the discretion of the Party having such difficulty.

Neither Party shall be considered in breach or default of this Agreement if and to the extent that any failure or delay in the Party’s performance of one or more of its obligations hereunder is caused by a Force Majeure Event. The occurrence and continuation of a Force Majeure Event shall not suspend or excuse the obligation of a Party to make any payments due hereunder.

10.3 Notice.

In the event of any delay or nonperformance resulting from a Force Majeure Event, the Party suffering the Force Majeure Event shall (a) as soon as practicable, notify the other Party in writing of the nature, cause, estimated date of commencement thereof, and the anticipated extent of any delay or interruption in performance, and (b) notify the other Party in writing of the cessation or termination of such Force Majeure Event, all as known or estimated in good faith by the affected Party; provided, a Party’s failure to give timely Notice shall not affect such Party’s ability to assert that a Force Majeure Event has occurred unless the delay in giving Notice materially prejudices the other Party.

10.4 Termination Following Force Majeure Event.

If a Force Majeure Event has occurred after the Commercial Operation Date that has caused either Party to be wholly or partially unable to perform its obligations hereunder in any material respect, and the impacted Party has claimed and received relief from performance of its obligations for a consecutive twelve (12) month period, then either Party may terminate this Agreement upon written Notice to the other Party. Upon any such termination, neither Party shall have any liability 52 to the other Party, save and except for those obligations specified in Section 2.1(b), and Buyer shall promptly return to Seller any Performance Security then held by Buyer, less any amounts drawn in accordance with this Agreement.

ARTICLE 11
DEFAULTS; REMEDIES; TERMINATION

11.1 Events of Default.

An “Event of Default” shall mean:
(a) with respect to a Party (the “Defaulting Party”) that is subject to the Event of Default the occurrence of any of the following:
(i) the failure by such Party to make, when due, any payment required pursuant to this Agreement and such failure is not remedied within ten (10) Business Days after Notice thereof;
(ii) any representation or warranty made by such Party herein is false or misleading in any material respect when made or when deemed made or repeated, and such default is not remedied within thirty (30) days after Notice thereof (or such longer additional period, not to exceed an additional sixty (60) days, if the Defaulting Party is unable to remedy such default within such initial thirty (30) day period despite exercising commercially reasonable efforts); (iii) the failure by such Party to perform any material covenant or obligation set forth in this Agreement (except to the extent constituting a separate Event of Default set forth in this Section 11.1; and except for (A) failure to provide Capacity Attributes, the exclusive remedies for which are set forth in Section Error! Reference source not found., (B) failures related to the Adjusted Energy Production that do not trigger the provisions of Section

11.1(b)(iii), the exclusive remedies for which are set forth in Section 4.7; and (C) failures related to the Annual Storage Capacity Availability that do not trigger the provisions of Section

11.1(b)(iv), the exclusive remedies for which are set forth in Section 4.8) and such failure is not remedied within thirty (30) days after Notice thereof (or such longer additional period, not to exceed an additional ninety (90) days, if the Defaulting Party is unable to remedy such default within such initial thirty (30) day period despite exercising commercially reasonable efforts); (iv) such Party becomes Bankrupt;
(v) such Party assigns this Agreement or any of its rights hereunder other than in compliance with Article 14, if applicable; or (vi) such Party consolidates or amalgamates with, or merges with or into, or transfers all or substantially all of its assets to, another entity and, at the time of such consolidation, amalgamation, merger or transfer, the resulting, surviving or transferee entity fails to assume all the obligations of such Party under this Agreement to which it or its predecessor was a party by operation of Law or pursuant to an agreement reasonably satisfactory to the other Party; 53 (b) with respect to Seller as the Defaulting Party, the occurrence of any of the following:
(i) if at any time, Seller delivers or attempts to deliver Energy to the Delivery Point for sale under this Agreement that was not generated or discharged by the Facility, except for Replacement Product;
(ii) the failure by Seller to (A) achieve Construction Start the Guaranteed Construction Start Date as may be extended by Seller’s payment of Daily Delay Damages pursuant to Section 1(b) of Exhibit B and/or a Development Cure Period pursuant to Section 4 of Exhibit B, or (B) achieve Commercial Operation on or before the Guaranteed Commercial Operation Date, as such date may be extended by Seller’s payment of Commercial Operation Delay Damages pursuant to Section 2 of Exhibit B and/or a Development Cure Period pursuant to Section 4 of Exhibit B;
(iii) if, in any Contract Year beginning with the second Contract Year, the Adjusted Energy Production amount (calculated in accordance with Exhibit G) for such period is not at least of the Expected Energy for such period, and Seller fails to (x) deliver to Buyer within ten (10) Business Days after Notice from Buyer a plan or report developed by Seller that describes the cause of the failure to meet the threshold and the actions that Seller has taken, is taking, or proposes to take in an effort to cure such condition along with the written confirmation of a Licensed Professional Engineer that such plan or report is in accordance with Prudent Operating Practices and capable of cure within a reasonable period of time, not to exceed one hundred eighty (180) days (“Cure Plan”) and (y) complete such Cure Plan in all material respects as set forth therein, including within the timeframe set forth therein; (iv) if, in any two (2) consecutive Contract Years during the Delivery Term, the Annual Storage Capacity Availability multiplied by the Effective Storage Capacity of the applicable period is not at least multiplied by the Installed Storage Capacity, and Seller fails to (x) deliver to Buyer within ten (10) Business Days after Notice from Buyer a plan or report developed by Seller that describes the cause of the failure to meet such multiplied by the Installed Storage Capacity threshold, and the actions that Seller has taken, is taking, or proposes to take in an effort to cure such condition along with the written confirmation of a Licensed Professional Engineer that such plan or report is in accordance with Prudent Operating Practices and capable of cure within a reasonable period of time, not to exceed days (“Storage Cure Plan”) and (y) complete such Storage Cure Plan in all material respects as set forth therein, including within the timeframe set forth therein; (v) failure by Seller to satisfy the collateral requirements pursuant to Sections 8.7 or 8.8 within five (5) Business Days after Notice from Buyer, including the failure to replenish the Performance Security amount in accordance with this Agreement in the event Buyer draws against it for any reason other than to satisfy a Termination Payment; (vi) with respect to any Guaranty provided for the benefit of Buyer, the failure by Seller to provide for the benefit of Buyer either (1) cash or (2) a replacement Letter of Credit from an issuer meeting the criteria set forth in the definition of Letter of Credit, in each 54 case, in the amount required hereunder within ten (10) Business Days after Seller receives Notice of the occurrence of any of the following events:
(A) if any representation or warranty made by the Guarantor in connection with this Agreement is false or misleading in any material respect when made or when deemed made or repeated, and such default is not remedied within thirty (30) days after Notice thereof; (B) the failure of the Guarantor to make any payment required or to perform any other material covenant or obligation in any Guaranty; (C) the Guarantor becomes Bankrupt;
(D) the Guarantor shall fail to meet the criteria for an acceptable Guarantor as set forth in the definition of Guarantor;
(E) the failure of the Guaranty to be in full force and effect (other than in accordance with its terms) prior to the indefeasible satisfaction of all obligations of Seller hereunder; or
(F) the Guarantor shall repudiate, disaffirm, disclaim, or reject, in whole or in part, or challenge the validity of any Guaranty; (vii) with respect to any outstanding Letter of Credit provided for the benefit of Buyer that is not then required under this Agreement to be canceled or returned, the failure by Seller to provide for the benefit of Buyer either (1) cash, or (2) a substitute Letter of Credit from a different issuer meeting the criteria set forth in the definition of Letter of Credit, in each case, in the amount required hereunder within ten (10) Business Days after Seller receives Notice of the occurrence of any of the following events:
(A) the issuer of the outstanding Letter of Credit shall fail to maintain a Credit Rating of at least A- by S&P or Fitch or A3 by Moody’s; (B) the issuer of such Letter of Credit becomes Bankrupt; (C) the issuer of the outstanding Letter of Credit shall fail to comply with or perform its obligations under such Letter of Credit and such failure shall be continuing after the lapse of any applicable grace period permitted under such Letter of Credit;
(D) the issuer of the outstanding Letter of Credit shall fail to honor a properly documented request to draw on such Letter of Credit; (E) the issuer of the outstanding Letter of Credit shall disaffirm, disclaim, repudiate or reject, in whole or in part, or challenge the validity of, such Letter of Credit;
55 (F) such Letter of Credit fails or ceases to be in full force and effect at any time; or
(G) Seller shall fail to renew or cause the renewal of each outstanding Letter of Credit on a timely basis as provided in the relevant Letter of Credit and as provided in accordance with this Agreement, and in no event less than sixty (60) days prior to the expiration of the outstanding Letter of Credit.
(c) with respect to Buyer as the Defaulting Party, the failure of Buyer to provide the Buyer Credit Support in accordance with Section 8.10(e), and such failure is not remedied within twenty (20) Business Days after Notice thereof.

11.2 Remedies; Declaration of Early Termination Date.

If an Event of Default with respect to a Defaulting Party shall have occurred and be continuing, the other Party (“Non-Defaulting Party”) shall have the following rights:
(a) to send Notice, designating a day, no earlier than the day such Notice is deemed to be received and no later than twenty (20) days after such Notice is deemed to be received, as an early termination date of this Agreement (“Early Termination Date”) that terminates this Agreement (the “Terminated Transaction”) and ends the Delivery Term effective as of the Early Termination Date;
(b) to accelerate all amounts owing between the Parties, and to collect as liquidated damages (i) the Damage Payment, or (ii) the Termination Payment, as applicable, in each case calculated in accordance with Section 11.3 below; (c) to withhold any payments due to the Defaulting Party under this Agreement; (d) to suspend performance; and
(e) to exercise any other right or remedy available at law or in equity, including specific performance or injunctive relief, except to the extent such remedies are expressly limited under this Agreement; provided, that payment by the Defaulting Party of the Damage Payment or Termination Payment, as applicable, shall constitute liquidated damages and the Non-Defaulting Party’s sole and exclusive remedy for any Terminated Transaction and the Event of Default related thereto.

11.3 Damage Payment; Termination Payment.

If an Early Termination Date has been declared, the Non-Defaulting Party shall calculate, in a commercially reasonable manner, the Damage Payment or Termination Payment, as applicable, in accordance with this Section 11.3.
(a) Damage Payment Prior to Commercial Operation Date. If the Early Termination Date occurs before the Commercial Operation Date, then the Damage Payment shall be calculated in accordance with this Section 11.3(a).
56 (i) If Seller is the Defaulting Party, then the Damage Payment shall be owed to Buyer and shall be equal to the entire Development Security amount and any interest accrued thereon; provided, in no event shall the sum of the Damage Payment and any Delay Damages paid to date exceed an amount equal to
Buyer shall be entitled to immediately retain for its own benefit those funds held as Development Security and any interest accrued thereon, and any amount of Development Security that Seller has not yet posted with Buyer will be immediately due and payable by Seller to Buyer. There will be no amounts owed to Seller. The Parties agree that Buyer’s damages in the event of an Early Termination Date prior to the Commercial Operation Date caused by Seller’s default would be difficult or impossible to determine and that the damages set forth in this Section 11.3(a)(i) are a reasonable approximation of Buyer’s harm or loss.
(ii) If Buyer is the Defaulting Party, then the Damage Payment shall be owed to Seller and shall equal the Settlement Amount plus any or all other amounts due to or from Buyer (as of the Early Termination Date), less the fair market value (determined in a commercially reasonable manner) of the Facility, regardless of whether or not Facility is actually sold or disposed of; provided that such Damage Payment shall not exceed the amount that Seller has posted as Development Security. There will be no amount owed to Buyer. The Parties agree that Seller’s damages in the event of an Early Termination Date prior to the Commercial Operation Date caused by Buyer’s default would be difficult or impossible to determine and that the damages set forth in this Section 11.3(a)(ii) are a reasonable approximation of Seller’s harm or loss. (b) Termination Payment On or After the Commercial Operation Date. The payment owed by the Defaulting Party to the Non-Defaulting Party for a Terminated Transaction occurring after the Commercial Operation Date (“Termination Payment”) shall be the aggregate of all Settlement Amounts plus any or all other amounts due to or from the Non-Defaulting Party (as of the Early Termination Date) netted into a single amount. The Non-Defaulting Party shall calculate, in a commercially reasonable manner, a Settlement Amount for the Terminated Transaction as of the Early Termination Date. Third parties supplying information for purposes of the calculation of Gains or Losses may include, without limitation, dealers in the relevant markets, end-users of the relevant product, information vendors and other sources of market information.

The Settlement Amount shall not include consequential, incidental, punitive, exemplary, indirect or business interruption damages. Without prejudice to the Non-Defaulting Party’s duty to mitigate, the Non-Defaulting Party shall not have to enter into replacement transactions to establish a Settlement Amount. Each Party agrees and acknowledges that (i) the actual damages that the Non-Defaulting Party would incur in connection with a Terminated Transaction would be difficult or impossible to predict with certainty, (ii) the Termination Payment described in this Section

11.3(b) is a reasonable and appropriate approximation of such damages, and (iii) the Termination Payment described in this Section 11.3(b) is the exclusive remedy of the Non-Defaulting Party in connection with a Terminated Transaction but shall not otherwise act to limit any of the Non-Defaulting Party’s rights or remedies if the Non-Defaulting Party does not elect a Terminated Transaction as its remedy for an Event of Default by the Defaulting Party.

11.4 Notice of Payment of Termination Payment or Damage Payment.

As soon as practicable after a Terminated Transaction, but in no event later than sixty (60) days after the Early Termination Date, Notice shall be given by the Non-Defaulting Party to the 57 Defaulting Party of the amount of the Damage Payment or Termination Payment, as applicable, and whether the Termination Payment or Damage Payment, as applicable, is due to or from the Non-Defaulting Party. The Notice shall include a written statement explaining in reasonable detail the calculation of such amount and the sources for such calculation. The Termination Payment or Damage Payment, as applicable, shall be made to or from the Non-Defaulting Party, as applicable, within ten (10) Business Days after such Notice is effective.

11.5 Disputes with Respect to Termination Payment or Damage Payment.

If the Defaulting Party disputes the Non-Defaulting Party’s calculation of the Termination Payment or Damage Payment, as applicable, in whole or in part, the Defaulting Party shall, within five (5) Business Days of receipt of the Non-Defaulting Party’s calculation of the Termination Payment or Damage Payment, as applicable, provide to the Non-Defaulting Party a detailed written explanation of the basis for such dispute. Disputes regarding the Termination Payment or Damage Payment, as applicable, shall be determined in accordance with Article 15.

11.6 Limitation on Seller’s Ability to Make or Agree to Third-Party Sales from the Facility after Early Termination Date.

If the Agreement is terminated by Buyer prior to the Commercial Operation Date due to Seller’s Event of Default, neither Seller nor Seller's Affiliates may sell, market or deliver any Product associated with or attributable to the Facility to a party other than Buyer for a period of two (2) years following the Early Termination Date due to Seller’s Event of Default, unless prior to selling, marketing or delivering such Product, or entering into the agreement to sell, market or deliver such Product to a party other than Buyer, Seller or Seller’s Affiliates provide Buyer with a written offer to sell the Product which provides Buyer the right to select in its sole discretion either the terms and conditions materially similar to the terms and conditions contained in this Agreement (including price) or the terms and conditions to which the third party agreed, and Buyer fails to accept such offer within forty-five (45) days of Buyer’s receipt thereof. Neither Seller nor Seller’s Affiliates may sell or transfer the Facility, or any part thereof, or land rights or interests in the Site (including the interconnection queue position of the Facility) so long as the limitations contained in this Section 11.6 apply, unless the transferee agrees to be bound by the terms set forth in this Section 11.6 pursuant to a written agreement approved by Buyer. Seller shall indemnify and hold Buyer harmless from all benefits lost and other damages sustained by Buyer as a result of any breach by Seller of its covenants contained within this Section 11.6.

11.7 Rights and Remedies Are Cumulative.

Except where liquidated damages or other remedy are explicitly provided as the exclusive remedy, the rights and remedies of a Party pursuant to this Article 11 shall be cumulative and in addition to the rights of the Parties otherwise provided in this Agreement.

11.8 Mitigation.

Any Non-Defaulting Party shall be obligated to use commercially reasonable efforts to mitigate its Costs, Losses and damages resulting from any Event of Default of the other Party under this Agreement.
58 11.9 Seller Pre-COD Termination.

12.1 No Consequential Damages.

EXCEPT TO THE EXTENT PART OF (A) AN EXPRESS REMEDY OR MEASURE OF DAMAGES HEREIN, (B) AN ARTICLE 16 INDEMNITY CLAIM, (C) INCLUDED IN A LIQUIDATED DAMAGES CALCULATION, OR (D) RESULTING FROM A PARTY’S

GROSS NEGLIGENCE OR WILLFUL MISCONDUCT, NEITHER PARTY SHALL BE

LIABLE TO THE OTHER OR ITS INDEMNIFIED PERSONS FOR ANY SPECIAL,

PUNITIVE, EXEMPLARY, INDIRECT, OR CONSEQUENTIAL DAMAGES, OR LOSSES OR

DAMAGES FOR LOST REVENUE OR LOST PROFITS, WHETHER FORESEEABLE OR

NOT, ARISING OUT OF, OR IN CONNECTION WITH THIS AGREEMENT, BY STATUTE, IN TORT OR CONTRACT.

12.2 Waiver and Exclusion of Other Damages.

EXCEPT AS EXPRESSLY SET FORTH HEREIN, THERE IS NO WARRANTY OF

MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE, AND ANY AND ALL IMPLIED WARRANTIES ARE DISCLAIMED. THE PARTIES CONFIRM THAT THE

EXPRESS REMEDIES AND MEASURES OF DAMAGES PROVIDED IN THIS AGREEMENT SATISFY THE ESSENTIAL PURPOSES HEREOF. ALL LIMITATIONS OF

LIABILITY CONTAINED IN THIS AGREEMENT, INCLUDING, WITHOUT LIMITATION, THOSE PERTAINING TO SELLER’S LIMITATION OF LIABILITY AND THE PARTIES’

WAIVER OF CONSEQUENTIAL DAMAGES, SHALL APPLY EVEN IF THE REMEDIES

FOR BREACH OF WARRANTY PROVIDED IN THIS AGREEMENT ARE DEEMED TO “FAIL OF THEIR ESSENTIAL PURPOSE” OR ARE OTHERWISE HELD TO BE INVALID OR UNENFORCEABLE.

FOR BREACH OF ANY PROVISION FOR WHICH AN EXPRESS AND EXCLUSIVE

REMEDY OR MEASURE OF DAMAGES IS PROVIDED, SUCH EXPRESS REMEDY OR

MEASURE OF DAMAGES SHALL BE THE SOLE AND EXCLUSIVE REMEDY, THE OBLIGOR’S LIABILITY SHALL BE LIMITED AS SET FORTH IN SUCH PROVISION, AND ALL OTHER REMEDIES OR DAMAGES AT LAW OR IN EQUITY ARE WAIVED.

IF NO REMEDY OR MEASURE OF DAMAGES IS EXPRESSLY PROVIDED HEREIN, THE OBLIGOR’S LIABILITY SHALL BE LIMITED TO DIRECT DAMAGES ONLY. THE VALUE OF ANY TAX CREDITS, DETERMINED ON AN AFTER-TAX BASIS, 59 LOST DUE TO BUYER’S DEFAULT (WHICH SELLER HAS NOT BEEN ABLE TO

MITIGATE AFTER USE OF REASONABLE EFFORTS) AND AMOUNTS DUE IN

CONNECTION WITH THE RECAPTURE OF ANY RENEWABLE ENERGY INCENTIVES, IF ANY, SHALL BE DEEMED TO BE DIRECT DAMAGES.

TO THE EXTENT ANY DAMAGES REQUIRED TO BE PAID HEREUNDER ARE LIQUIDATED, INCLUDING UNDER SECTIONS Error! Reference source not found., 4.7,

4.8, 11.2 AND 11.3, AND AS PROVIDED IN EXHIBIT B, EXHIBIT C, EXHIBIT G, AND

EXHIBIT P, THE PARTIES ACKNOWLEDGE THAT THE DAMAGES ARE DIFFICULT OR

IMPOSSIBLE TO DETERMINE, THAT OTHERWISE OBTAINING AN ADEQUATE

REMEDY IS INCONVENIENT, AND THAT THE LIQUIDATED DAMAGES CONSTITUTE A REASONABLE APPROXIMATION OF THE ANTICIPATED HARM OR LOSS. IT IS THE

INTENT OF THE PARTIES THAT THE LIMITATIONS HEREIN IMPOSED ON REMEDIES

AND THE MEASURE OF DAMAGES BE WITHOUT REGARD TO THE CAUSE OR

CAUSES RELATED THERETO, INCLUDING THE NEGLIGENCE OF ANY PARTY,

WHETHER SUCH NEGLIGENCE BE SOLE, JOINT OR CONCURRENT, OR ACTIVE OR PASSIVE. THE PARTIES HEREBY WAIVE ANY RIGHT TO CONTEST SUCH PAYMENTS AS AN UNREASONABLE PENALTY.

THE PARTIES ACKNOWLEDGE AND AGREE THAT MONEY DAMAGES AND

THE EXPRESS REMEDIES PROVIDED FOR HEREIN ARE AN ADEQUATE REMEDY FOR

THE BREACH BY THE OTHER OF THE TERMS OF THIS AGREEMENT, AND EACH

PARTY WAIVES ANY RIGHT IT MAY HAVE TO SPECIFIC PERFORMANCE WITH RESPECT TO ANY OBLIGATION OF THE OTHER PARTY UNDER THIS AGREEMENT.

ARTICLE 13
REPRESENTATIONS AND WARRANTIES; AUTHORITY

13.1 Seller’s Representations and Warranties.

As of the Effective Date, Seller represents and warrants as follows:
(a) Seller is a limited liability company, duly organized, validly existing and in good standing under the laws of the jurisdiction of its formation, and is qualified to conduct business in each jurisdiction where the failure to so qualify would have a material adverse effect on the business or financial condition of Seller.
(b) Seller has the power and authority to enter into and perform this Agreement and is not prohibited from entering into this Agreement or discharging and performing all covenants and obligations on its part to be performed under and pursuant to this Agreement, except where such failure does not have a material adverse effect on Seller’s performance under this Agreement. The execution, delivery and performance of this Agreement by Seller has been duly authorized by all necessary limited liability company action on the part of Seller and does not and will not require the consent of any trustee or holder of any indebtedness or other obligation of Seller or any other party to any other agreement with Seller. (c) The execution and delivery of this Agreement, consummation of the transactions contemplated herein, and fulfillment of and compliance by Seller with the provisions 60 of this Agreement will not conflict with or constitute a breach of or a default under any Law presently in effect having applicability to Seller, subject to any permits that have not yet been obtained by Seller, the documents of formation of Seller or any outstanding trust indenture, deed of trust, mortgage, loan agreement or other evidence of indebtedness or any other agreement or instrument to which Seller is a party or by which any of its property is bound. (d) This Agreement has been duly executed and delivered by Seller. This Agreement is a legal, valid and binding obligation of Seller enforceable in accordance with its terms, except as limited by laws of general applicability limiting the enforcement of creditors’ rights or by the exercise of judicial discretion in accordance with general principles of equity. (e) The Facility is located in the State of California.

13.2 Buyer’s Representations and Warranties.

As of the Effective Date, Buyer represents and warrants as follows:
(a) Buyer is a joint powers authority and a validly existing community choice aggregator, duly organized, validly existing and in good standing under the laws of the State of California and the rules, regulations and orders of the California Public Utilities Commission, and is qualified to conduct business in each jurisdiction of the Joint Powers Agreement members. All Persons making up the governing body of Buyer are the elected or appointed incumbents in their positions and hold their positions in good standing in accordance with the Joint Powers Agreement and other Law.
(b) Buyer has the power and authority to enter into and perform this Agreement and is not prohibited from entering into this Agreement or discharging and performing all covenants and obligations on its part to be performed under and pursuant to this Agreement, except where such failure does not have a material adverse effect on Buyer’s performance under this Agreement. The execution, delivery and performance of this Agreement by Buyer has been duly authorized by all necessary action on the part of Buyer and does not and will not require the consent of any trustee or holder of any indebtedness or other obligation of Buyer or any other party to any other agreement with Buyer.
(c) The execution and delivery of this Agreement, consummation of the transactions contemplated herein, and fulfillment of and compliance by Buyer with the provisions of this Agreement will not conflict with or constitute a breach of or a default under any Law presently in effect having applicability to Buyer, including but not limited to community choice aggregation, the Joint Powers Act, competitive bidding, public notice, open meetings, election, referendum, or prior appropriation requirements, the documents of formation of Buyer or any outstanding trust indenture, deed of trust, mortgage, loan agreement or other evidence of indebtedness or any other agreement or instrument to which Buyer is a party or by which any of its property is bound.
(d) This Agreement has been duly executed and delivered by Buyer. This Agreement is a legal, valid and binding obligation of Buyer enforceable in accordance with its terms, except as limited by laws of general applicability limiting the enforcement of creditors’ rights or by the exercise of judicial discretion in accordance with general principles of equity. 61 (e) Buyer warrants and covenants that with respect to its contractual obligations under this Agreement, it will not claim immunity on the grounds of sovereignty or similar grounds with respect to itself or its revenues or assets from (1) suit, (2) jurisdiction of court, (3) relief by way of injunction, order for specific performance or recovery of property, (4) attachment of assets, or (5) execution or enforcement of any judgment.
(f) Buyer is a “local public entity” as defined in Section 900.4 of the Government Code of the State of California.
(g) Buyer cannot assert sovereign immunity as a defense to the enforcement of its obligations under this Agreement.

13.3 General Covenants.

Each Party covenants that commencing on the Effective Date and continuing throughout the Contract Term:
(a) It shall continue to be duly organized, validly existing and in good standing under the laws of the jurisdiction of its formation and to be qualified to conduct business in each jurisdiction where the failure to so qualify would have a material adverse effect on its business or financial condition;
(b) It shall maintain (or obtain from time to time as required) all regulatory authorizations necessary for it to legally perform its obligations under this Agreement; and (c) It shall perform its obligations under this Agreement in compliance with all terms and conditions in its governing documents and in material compliance with any Law.

13.4 Workforce Development.

The Parties acknowledge that in connection with Buyer’s renewable energy procurement efforts, including entering into this Agreement, Buyer is committed to creating community benefits, which includes engaging a skilled and trained workforce and targeted hires. Accordingly, on December 1st of each of the first ten (10) years in the Delivery Term, Seller shall cause twenty thousand dollars ($20,000) to be deposited, for a total of two hundred thousand dollars ($200,000), into a “Workforce Development Fund” maintained by Buyer. The investment plan for utilizing such funds shall be developed by Buyer at the discretion of Buyer’s board. Seller shall comply with all federal, state and local laws, statutes, ordinances, rules and regulations, and the orders and decrees of any courts or administrative bodies or tribunals, including, without limitation employment discrimination laws and prevailing wage laws. If requested by Buyer, Seller shall complete a “Supplier Diversity and Labor Practices” questionnaire, and Seller agrees to comply with similar regular reporting requirements related to diversity and labor practices.

13.5 Local Sustainability.

The Parties acknowledge that in connection with Buyer’s renewable energy procurement efforts, including entering into this Agreement, Buyer is committed to supporting local sustainability efforts. Accordingly, on December 1st of each of the first ten (10) years in the 62 Delivery Term, Seller shall cause ten thousand dollars ($10,000) to be deposited, for a total of one hundred thousand dollars ($100,000), into a “Local Sustainability Fund” maintained by Buyer.

The investment plan for utilizing such funds shall be developed by Buyer at the discretion of Buyer’s board.

ARTICLE 14

ASSIGNMENT

14.1 General Prohibition on Assignments.

Except as provided below in this Article 14, neither Party may voluntarily assign this Agreement or its rights or obligations under this Agreement, without the prior written consent of the other Party, which consent shall not be unreasonably withheld, conditioned or delayed. Any Change of Control of Seller (whether voluntary or by operation of law) will be deemed an assignment and will require the prior written consent of Buyer, which consent shall not be unreasonably withheld, conditioned or delayed; provided, a Change of Control of Seller shall not require Buyer’s consent if the assignee or transferee is a Permitted Transferee or if it is a Permitted Transfer. Any assignment made without the required written consent, or in violation of the conditions to assignment set out below, shall be null and void. Seller shall be responsible for Buyer’s reasonable costs associated with the preparation, review, execution and delivery of documents in connection with any assignment of this Agreement by Seller, including without limitation reasonable attorneys’ fees.

14.2 Collateral Assignment.

Subject to the provisions of this Section 14.2, Seller has the right to assign this Agreement as collateral for any financing or refinancing of the Facility. In connection with any financing or refinancing of the Facility by Seller, Buyer shall in good faith work with Seller and Lender to agree upon a consent to collateral assignment of this Agreement in substantially the form attached as Exhibit S (“Collateral Assignment Agreement”).

14.3 Permitted Assignment by Seller.

Seller may, without the prior written consent of Buyer, transfer or assign this Agreement to: (a) an Affiliate of Seller or (b) any Person succeeding to all or substantially all of the assets of Seller (whether voluntary or by operation of law); if, and only if:
(i) the assignee is a Permitted Transferee;
(ii) Seller has given Buyer Notice at least fifteen (15) Business Days before the date of such proposed assignment; and
(iii) Seller has provided Buyer a written agreement signed by the Person to which Seller wishes to assign its interests that (x) provides that such Person will assume all of Seller’s obligations and liabilities under this Agreement upon such transfer or assignment and (y) certifies that such Person meets the definition of a Permitted Transferee. 63 Notwithstanding the foregoing, any assignment by Seller, its successors or assigns under this Section 14.3 shall be of no force and effect unless and until such Notice and agreement by the assignee have been received and accepted by Buyer.

14.4 Permitted Transfer by Seller.

Seller may make a Permitted Transfer, without the prior written consent of Buyer, provided that Seller gives at least thirty (30) days’ prior written notice to Buyer.

14.5 Shared Facilities; Portfolio Financing.

Buyer agrees and acknowledges that Seller may elect to finance all or any portion of the Facility or the Interconnection Facilities or the Shared Facilities (1) utilizing tax equity investment, and/or (2) through a Portfolio Financing, which may include cross-collateralization or similar arrangements. In connection with any financing or refinancing of the Facility, the Interconnection Facilities or the Shared Facilities by Seller or any Portfolio Financing, Buyer, Seller, Portfolio Financing Entity (if any), and Lender shall execute and deliver such further consents, approvals and acknowledgments as may be reasonable and necessary to facilitate such transactions; provided, Buyer shall not be required to agree to any terms or conditions which are reasonably expected to have a material adverse effect on Buyer and all reasonable attorney’s fees incurred by Buyer in connection therewith shall be borne by Seller.

ARTICLE 15

DISPUTE RESOLUTION

15.1 Governing Law.

This Agreement and the rights and duties of the Parties hereunder shall be governed by and construed, enforced and performed in accordance with the laws of the state of California, without regard to principles of conflicts of Law. To the extent enforceable at such time, each Party waives its respective right to any jury trial with respect to any litigation arising under or in connection with this Agreement.

15.2 Dispute Resolution.

In the event of any dispute arising under this Agreement, within ten (10) days following the receipt of a written Notice from either Party identifying such dispute, the Parties shall meet, negotiate and attempt, in good faith, to resolve the dispute quickly, informally and inexpensively.

If the Parties are unable to resolve a dispute arising hereunder within the earlier of either thirty (30) days of initiating such discussions, or within forty (40) days after Notice of the dispute, either Party may seek any and all remedies available to it at law or in equity, subject to the limitations set forth in this Agreement.

15.3 Attorneys’ Fees.

In any proceeding brought to enforce this Agreement or because of the breach by any Party of any covenant or condition herein contained, the prevailing Party shall be entitled to reasonable 64 attorneys’ fees (including reasonably allocated fees of in-house counsel) in addition to court costs and any and all other costs recoverable in said action.

ARTICLE 16

INDEMNIFICATION

16.1 Indemnification.
(a) Each Party (the “Indemnifying Party”) agrees to indemnify, defend and hold harmless the other Party and its Affiliates, directors, officers, employees and agents (collectively, the “Indemnified Party”) from and against all claims, demands, losses, liabilities, penalties, and expenses (including reasonable attorneys’ fees) (i) for personal injury or death to Persons and damage to the property of any third party to the extent arising out of, resulting from, or caused by the negligent or willful misconduct of the Indemnifying Party, its Affiliates, its directors, officers, employees, or agents, or (ii) for third-party claims resulting from the Indemnifying Party’s breach (including inaccuracy of any representation of warranty made hereunder), performance or non-performance of its obligations under this Agreement. (b) Nothing in this Section 16.1 shall enlarge or relieve Seller or Buyer of any liability to the other for any breach of this Agreement. Neither Party shall be indemnified for its damages resulting from its sole negligence, intentional acts or willful misconduct. These indemnity provisions shall not be construed to relieve any insurer of its obligation to pay claims consistent with the provisions of a valid insurance policy.

16.2 Claims.

Promptly after receipt by a Party of any claim or Notice of the commencement of any action, administrative, or legal proceeding, or investigation as to which the indemnity provided for in this Article 16 may apply, the Indemnified Party shall notify the Indemnifying Party in writing of such fact. The Indemnifying Party shall assume the defense thereof with counsel designated by the Indemnifying Party and satisfactory to the Indemnified Party, provided, if the defendants in any such action include both the Indemnified Party and the Indemnifying Party and the Indemnified Party shall have reasonably concluded that there may be legal defenses available to it which are different from or additional to, or inconsistent with, those available to the Indemnifying Party, the Indemnified Party shall have the right to select and be represented by separate counsel, at the Indemnifying Party’s expense, unless a liability insurer is willing to pay such costs. If the Indemnifying Party fails to assume the defense of a claim meriting indemnification, the Indemnified Party may at the expense of the Indemnifying Party contest, settle, or pay such claim, provided that settlement or full payment of any such claim may be made only following consent of the Indemnifying Party or, absent such consent, written opinion of the Indemnified Party’s counsel that such claim is meritorious or warrants settlement. Except as otherwise provided in this Article 16, in the event that a Party is obligated to indemnify and hold the other Party and its successors and assigns harmless under this Article 16, the amount owing to the Indemnified Party will be the amount of the Indemnified Party’s damages net of any insurance proceeds received by the Indemnified Party following a reasonable effort by the Indemnified Party to obtain such insurance proceeds.
65 ARTICLE 17

INSURANCE

17.1 Insurance.
(a) General Liability. Seller shall maintain, or cause to be maintained at its sole expense, (i) commercial general liability insurance, including products and completed operations and personal injury insurance, in a minimum amount of
endorsed
to provide contractual liability in said amount, specifically covering Seller’s obligations under this Agreement and including Buyer as an additional insured; and (ii) an umbrella or excess insurance policy in a minimum limit of liability of Defense costs shall be provided as an additional benefit and not included within the limits of liability. Such insurance shall contain standard cross-liability and severability of interest provisions. (b) Employer’s Liability Insurance. Employers’ Liability insurance shall not be for injury or death occurring as a result of each
accident. With regard to bodily injury by disease, the policy limit will apply to each employee.
(c) Workers Compensation Insurance. Seller, if it has employees, shall also maintain at all times during the Contract Term workers’ compensation and employers’ liability insurance coverage in accordance with applicable requirements of Law. (d) Business Auto Insurance. Seller shall maintain at all times during the Contract Term business auto insurance for bodily injury and property damage with a combined single limit of per occurrence. Such insurance shall cover liability arising out of Seller’s use of all owned (if any), non-owned and hired vehicles, including trailers or semi-trailers in the performance of the Agreement. (e) Builder’s All-Risk Insurance. Seller shall maintain or cause to be maintained during the construction of the Facility prior to the Commercial Operation Date, builder’s all-risk form property insurance covering the Facility during such construction periods, and naming Seller (and Lender if any) as the loss payee. (f) Subcontractor Insurance. Seller shall require all of its subcontractors to carry: (i) commercial general liability insurance with a combined single limit of coverage (ii) workers’ compensation insurance and employers’
liability coverage in accordance with applicable requirements of Law; and (iii) business auto insurance for bodily injury and property damage with limits of per occurrence. All subcontractors shall include Seller as an additional insured to insurance carried pursuant to clauses (f)(i) and (f)(iii). All subcontractors shall provide a primary endorsement and a waiver of subrogation to Seller for the required coverage pursuant to this Section 17.1(f). (g) Evidence of Insurance. Within ten (10) days after execution of the Agreement and upon annual renewal thereafter, Seller shall deliver to Buyer certificates of insurance evidencing such coverage. Such certificates shall specify that Buyer shall be given at least thirty (30) days prior Notice by Seller in the event of any material modification, cancellation 66 or termination of coverage. Such insurance shall be primary coverage without right of contribution from any insurance of Buyer. Any other insurance maintained by Seller is for the exclusive benefit of Seller and shall not in any manner inure to the benefit of Buyer. The general liability, auto liability and worker’s compensation policies shall be endorsed with a waiver of subrogation in favor of Buyer for all work performed by Seller, its employees, agents and sub-contractors. (h) Failure to Comply with Insurance Requirements. If Seller fails to comply with any of the provisions of this Article 17, Seller, among other things and without restricting Buyer’s remedies under the Law or otherwise, shall, at its own cost and expense, act as an insurer and self-insure in accordance with the terms and conditions above. With respect to the required general liability, umbrella or excess liability and business automobile liability insurance, Seller shall provide a current, full and complete defense to Buyer, its subsidiaries and Affiliates, and their respective officers, directors, shareholders, agents, employees, assigns, and successors in interest, in response to a third-party claim in the same manner that an insurer would have, had the insurance been maintained in accordance with the terms and conditions set forth above. In addition, alleged violations of the provisions of this Article 17 means that Seller has the initial burden of proof regarding any legal justification for refusing or withholding coverage and Seller shall face the same liability and damages as an insurer for wrongfully refusing or withholding coverage in accordance with the laws of California.

ARTICLE 18

CONFIDENTIAL INFORMATION

18.1 Definition of Confidential Information.

The following constitutes “Confidential Information,” whether oral or written which is delivered by Seller to Buyer or by Buyer to Seller including: (a) the terms and conditions of, and proposals and negotiations related to, this Agreement, and (b) information that either Seller or Buyer stamps or otherwise identifies as “confidential” or “proprietary” before disclosing it to the other. Confidential Information does not include (i) information that was publicly available at the time of the disclosure, other than as a result of a disclosure in breach of this Agreement; (ii) information that becomes publicly available through no fault of the recipient after the time of the delivery; (iii) information that was rightfully in the possession of the recipient (without confidential or proprietary restriction) at the time of delivery or that becomes available to the recipient from a source not subject to any restriction against disclosing such information to the recipient; and (iv) information that the recipient independently developed without a violation of this Agreement.

18.2 Duty to Maintain Confidentiality.

The Party receiving Confidential Information (the “Receiving Party”) from the other Party (the “Disclosing Party”) shall not disclose Confidential Information to a third party (other than the Party’s employees, lenders, counsel, accountants, directors or advisors, or any such representatives of a Party’s Affiliates, who have a need to know such information and have agreed to keep such terms confidential) except in order to comply with any applicable Law, regulation, or any exchange, control area or independent system operator rule or in connection with any court or regulatory proceeding applicable to such Party or any of its Affiliates; provided, each Party shall, 67 to the extent practicable, use reasonable efforts to prevent or limit the disclosure. The Parties shall be entitled to all remedies available at law or in equity to enforce, or seek relief in connection with, this confidentiality obligation. The Parties agree and acknowledge that nothing in this Section 18.2 prohibits a Party from disclosing any one or more of the commercial terms of a transaction (other than the name of the other Party unless otherwise agreed to in writing by the Parties) to any industry price source for the purpose of aggregating and reporting such information in the form of a published energy price index.

The Parties acknowledge and agree that the Agreement and any transactions entered into in connection herewith are subject to the requirements of the California Public Records Act (Government Code Section 6250 et seq.). In order to designate information as confidential, the Disclosing Party must clearly stamp and identify the specific portion of the material designated with the word “Confidential.” The Parties agree not to over-designate material as Confidential Information. Over-designation includes stamping whole agreements, entire pages or series of pages as “Confidential” that clearly contain information that is not Confidential Information.

Upon request or demand of any third person or entity not a Party hereto to Buyer pursuant to the California Public Records Act for production, inspection and/or copying of Confidential Information (“Requested Confidential Information”), Buyer will as soon as practical notify Seller in writing via email that such request has been made. Seller will be solely responsible for taking at its sole expense whatever legal steps are necessary to prevent release of the Requested Confidential Information to the third party by Buyer. If Seller takes no such action after receiving the foregoing notice from Buyer, Buyer shall, at its discretion, be permitted to comply with the third party’s request or demand and is not required to defend against it. If Seller does take or attempt to take such action, Buyer shall provide timely and reasonable cooperation to Seller, if requested by Seller, and Seller agrees to indemnify and hold harmless Buyer, its officers, employees and agents (“Buyer’s Indemnified Parties”), from any claims, liability, award of attorneys’ fees, or damages, and to defend any action, claim or lawsuit brought against any of Buyer’s Indemnified Parties for Buyer’s refusal to disclose any Requested Confidential Information.

18.3 Irreparable Injury; Remedies.

Receiving Party acknowledges that its obligations hereunder are necessary and reasonable in order to protect Disclosing Party and the business of Disclosing Party, and expressly acknowledges that monetary damages would be inadequate to compensate Disclosing Party for any breach or threatened breach by Receiving Party of any covenants and agreements set forth herein. Accordingly, Receiving Party acknowledges that any such breach or threatened breach will cause irreparable injury to Disclosing Party and that, in addition to any other remedies that may be available, in law, in equity or otherwise, Disclosing Party will be entitled to obtain injunctive relief against the threatened breach of this Agreement or the continuation of any such breach, without the necessity of proving actual damages.

18.4 Further Permitted Disclosure.

Notwithstanding anything to the contrary in this Article 18, Confidential Information may be disclosed by the Receiving Party to any of its agents, consultants, contractors, trustees, or actual 68 or potential financing parties (including, in the case of Seller, its Lender(s)), so long as such Person to whom Confidential Information is disclosed agrees in writing to be bound by confidentiality provisions that are at least as restrictive as this Article 18 to the same extent as if it were a Party.

18.5 Press Releases.

Neither Party shall issue (or cause its Affiliates to issue) a press release regarding the transactions contemplated by this Agreement unless both Parties have agreed upon the contents of any such public statement.

ARTICLE 19

MISCELLANEOUS

19.1 Entire Agreement; Integration; Exhibits.

This Agreement, together with the Cover Sheet and Exhibits attached hereto constitutes the entire agreement and understanding between Seller and Buyer with respect to the subject matter hereof and supersedes all prior agreements relating to the subject matter hereof, which are of no further force or effect. The Exhibits attached hereto are integral parts hereof and are made a part of this Agreement by reference. The headings used herein are for convenience and reference purposes only. In the event of a conflict between the provisions of this Agreement and those of the Cover Sheet or any Exhibit, the provisions of first the Cover Sheet, and then this Agreement shall prevail, and such Exhibit shall be corrected accordingly. This Agreement shall be considered for all purposes as prepared through the joint efforts of the Parties and shall not be construed against one Party or the other as a result of the preparation, substitution, submission or other event of negotiation, drafting or execution hereof.

19.2 Amendments.

This Agreement may only be amended, modified or supplemented by an instrument in writing executed by duly authorized representatives of Seller and Buyer; provided, this Agreement may not be amended by electronic mail communications.

19.3 No Waiver.

Waiver by a Party of any default by the other Party shall not be construed as a waiver of any other default.

19.4 No Agency, Partnership, Joint Venture or Lease.

Seller and the agents and employees of Seller shall, in the performance of this Agreement, act in an independent capacity and not as officers or employees or agents of Buyer. Under this Agreement, Seller and Buyer intend to act as energy seller and energy purchaser, respectively, and do not intend to be treated as, and shall not act as, partners in, co-venturers in or lessor/lessee with respect to the Facility or any business related to the Facility. This Agreement shall not impart any rights enforceable by any third party (other than a permitted successor or assignee bound to this Agreement) and/or, to the extent set forth herein, any Lender and/or Indemnified Party. 69 19.5 Severability.

In the event that any provision of this Agreement is unenforceable or held to be unenforceable, the Parties agree that all other provisions of this Agreement have force and effect and shall not be affected thereby. The Parties shall, however, use their best endeavors to agree on the replacement of the void, illegal or unenforceable provision(s) with legally acceptable clauses which correspond as closely as possible to the sense and purpose of the affected provision and this Agreement as a whole.

19.6 Mobile-Sierra.

Notwithstanding any other provision of this Agreement, neither Party shall seek, nor shall they support any third party seeking, to prospectively or retroactively revise the rates, terms or conditions of service of this Agreement through application or complaint to FERC pursuant to the provisions of Section 205, 206 or 306 of the Federal Power Act, or any other provisions of the Federal Power Act, absent prior written agreement of the Parties. Further, absent the prior written agreement in writing by both Parties, the standard of review for changes to the rates, terms or conditions of service of this Agreement proposed by a Party shall be the “public interest” standard of review set forth in United Gas Pipe Line Co. v. Mobile Gas Service Corp., 350 U.S. 332 (1956) and Federal Power Commission v. Sierra Pacific Power Co., 350 U.S. 348 (1956). Changes proposed by a non-Party or FERC acting sua sponte shall be subject to the most stringent standard permissible under applicable Law.

19.7 Counterparts.

This Agreement may be executed in one or more counterparts, all of which taken together shall constitute one and the same instrument and each of which shall be deemed an original.

19.8 Electronic Delivery.

This Agreement may be duly executed and delivered by a Party by electronic format (including portable document format (.pdf)) delivery of the signature page of a counterpart to the other Party, and, if delivery is made by electronic format, the executing Party shall promptly deliver, via overnight delivery, a complete original counterpart that it has executed to the other Party, but this Agreement shall be binding on and enforceable against the executing Party whether or not it delivers such original counterpart.

19.9 Binding Effect.

This Agreement shall inure to the benefit of and be binding upon the Parties and their respective successors and permitted assigns.

19.10 No Recourse to Members of Buyer.

Buyer is organized as a Joint Powers Authority in accordance with the Joint Exercise of Powers Act of the State of California (Government Code Section 6500, et seq.) pursuant to its Joint Powers Agreement and is a public entity separate from its constituent members. Buyer shall solely be responsible for all debts, obligations and liabilities accruing and arising out of this 70 Agreement. Seller shall have no rights and shall not make any claims, take any actions or assert any remedies against any of Buyer’s constituent members, or the employees, directors, officers, consultants or advisors of Buyer or its constituent members, in connection with this Agreement.

19.11 Forward Contract.

The Parties acknowledge and agree that this Agreement constitutes a “forward contract” within the meaning of the U.S. Bankruptcy Code, and Buyer and Seller are “forward contract merchants” within the meaning of the U.S. Bankruptcy Code. Each Party further agrees that, for all purposes of this Agreement, each Party waives and agrees not to assert the applicability of the provisions of 11 U.S.C. § 366 in any Bankruptcy proceeding wherein such Party is a debtor. In any such proceeding, each Party further waives the right to assert that the other Party is a provider of last resort to the extent such term relates to 11 U.S.C. §366 or another provision of 11 U.S.C. § 101-1532.

19.12 Change in Electric Market Design.

If a change in the CAISO Tariff renders this Agreement or any provisions hereof incapable of being performed or administered, then any Party may request that Buyer and Seller enter into negotiations to make the minimum changes to this Agreement necessary to make this Agreement capable of being performed and administered, while attempting to preserve to the maximum extent possible the benefits, burdens, and obligations set forth in this Agreement as of the Effective Date.

Upon delivery of such a request, Buyer and Seller shall engage in such negotiations in good faith.

If Buyer and Seller are unable, within sixty (60) days after delivery of such request, to agree upon changes to this Agreement or to resolve issues relating to changes to this Agreement, then any Party may submit issues pertaining to changes to this Agreement to the dispute resolution process set forth in Article 15. Notwithstanding the foregoing, (i) a change in cost shall not in and of itself be deemed to render this Agreement or any of the provisions hereof incapable of being performed or administered, and (ii) all of the unaffected provisions of this Agreement shall remain in full force and effect during any period of such negotiation or dispute resolution.

19.13 Further Assurances.

Each of the Parties hereto agrees to provide such information, execute and deliver any instruments and documents and to take such other actions as may be necessary or reasonably requested by the other Party which are not inconsistent with the provisions of this Agreement and which do not involve the assumptions of obligations other than those provided for in this Agreement, to give full effect to this Agreement and to carry out the intent of this Agreement. [Signatures on following page]
IN WITNESS WHEREOF, the Parties have caused this Agreement to be duly executed as of the Effective Date.

RESURGENCE SOLAR I, LLC
By:

Name:

Title:

VALLEY CLEAN ENERGY ALLIANCE
By:

Name:

Title:

Exhibit A - 1

EXHIBIT A

FACILITY DESCRIPTION
Site Name: Resurgence Solar I
Site includes all or some of the following APNs: 0491-101-16-0000, 0491-101-17-0000, 0491- 101-18-0000, 0491-101-19-000, 0491-151-38-0000, 0491-151-39-0000, 0491-151-40-0000, 0498-171-05-0000, 0498-171-06-0000
City: Boron
County: San Bernardino, CA
Zip Code: 93516
Latitude and Longitude: 35.0131, -117.5487
Facility Description: A solar photovoltaic electric generating facility with a net nameplate capacity of 90 MW AC coupled with a lithium ion (Li-Ion) battery storage facility with a net nameplate capacity of 75 MW AC / 300 MWh located near the City of Boron within San Bernardino County, California. The Facility is a portion of a larger 138 – 150 MW solar + storage project. Seller may install additional inverter capacity to account for production and delivery losses.

Site Diagram: Attached
Delivery Point: P-node
Generating Facility Metering Points: See Exhibit R
Storage Facility Metering Points: See Exhibit R
P-node: To be established prior to the Commercial Operation Date at the Kramer Junction 115kV bus. Seller shall promptly notify Buyer following the establishment of the P-node.

Transmission Provider: Southern California Edison
Additional Information: None
2 Site Diagram:

Exhibit B - 1

EXHIBIT B

FACILITY CONSTRUCTION AND COMMERCIAL OPERATION

1. Construction of the Facility.
a. “Construction Start” will occur upon Seller’s acquisition of all applicable regulatory authorizations, approvals and permits for the construction of the Facility, and once Seller has engaged all primary contractors and ordered all major equipment and supplies as, in each case, can reasonably be considered necessary so that physical construction of the Facility may begin and proceed to completion without foreseeable interruption of material duration, and has executed an engineering, procurement, and construction contract and issued thereunder a final notice to proceed that authorizes the contractor to mobilize to Site and begin physical construction (including, at a minimum, excavation for foundations or the installation or erection of improvements) at the Site. The date of Construction Start will be evidenced by and subject to Seller’s delivery to Buyer of a certificate substantially in the form attached as Exhibit J hereto, and the date certified therein shall be the “Construction Start Date.” Seller shall cause Construction Start to occur no later than the Guaranteed Construction Start Date. b. Seller may extend the Guaranteed Construction Start Date by paying Daily Delay Damages to Buyer for each day Seller desires to extend the Guaranteed Construction Start Date, not to exceed a total of of
extensions by such payment of Daily Delay Damages. On or before the tenth (10th) day of each month, Buyer shall invoice Seller for Daily Delay Damages, if any, accrued during the prior month and, within ten (10) Business Days following Seller’s receipt of such invoice, Seller shall pay Buyer the amount of the Daily Delay Damages set forth in such invoice. If Seller achieves Commercial Operation on or before the Guaranteed Commercial Operation Date (including any extensions to such date resulting from Seller’s payment of Commercial Operation Delay Damages, and as may be extended pursuant to a Development Cure Period), then Buyer shall refund to Seller all Daily Delay Damages paid by Seller.

2. Commercial Operation of the Facility. “Commercial Operation” means the condition existing when Seller has fulfilled all of the conditions precedent in Section 2.2 of the Agreement and provided Notice to Buyer substantially in the form of Exhibit H (the “COD Certificate”).
a. Seller shall cause Commercial Operation for the Facility to occur by the Guaranteed Commercial Operation Date. Seller shall notify Buyer that it intends to achieve Commercial Operation at least sixty (60) days before the anticipated Commercial Operation Date.
b. Seller may extend the Guaranteed Commercial Operation Date by paying Commercial Operation Delay Damages to Buyer for each day Seller desires to extend the Guaranteed Commercial Operation Date, not to exceed a total of by such payment of Commercial Operation Delay
Exhibit B - 2
Damages. On or before the tenth (10th) day of each month, Buyer shall invoice Seller for Commercial Operation Delay Damages, if any, accrued during the prior month. Notwithstanding anything in this Agreement to the contrary, the aggregate Delay Damages shall not exceed the amount of the Development Security.

3. Termination for Failure to Achieve Commercial Operation. If the Facility has not achieved Commercial Operation on or before the Guaranteed Commercial Operation Date (as may be extended hereunder), Buyer may elect to terminate this Agreement in accordance with Sections 11.1(b)(ii) and 11.2.

4. Extension of the Guaranteed Dates. The Guaranteed Construction Start Date and the Guaranteed Commercial Operation Date shall, subject to notice and documentation requirements set forth below, be automatically extended on a day-for-day basis (the “Development Cure Period”) for the duration of any and all delays arising out of the following circumstances to the extent the following circumstances are not the result of Seller’s failure to take all commercially reasonable actions to meet its requirements and deadlines:
a. Seller has not acquired by the Expected Construction Start Date all material permits, consents, licenses, approvals, or authorizations from any Governmental Authority required for Seller to own, construct, interconnect, operate or maintain the Facility and to permit Seller and the Facility to make available and sell Product, despite the exercise of diligent and commercially reasonable efforts by Seller; or b. a Force Majeure Event occurs; or
c. the Interconnection Facilities or Reliability Network Upgrades are not complete and ready for the Facility to connect and sell Product at the Delivery Point by the Guaranteed Commercial Operation Date, despite the exercise of diligent and commercially reasonable efforts by Seller; or
d. Buyer has not made all necessary arrangements to receive the Facility Energy at the Delivery Point by the Guaranteed Commercial Operation Date.

Notwithstanding anything in this Agreement to the contrary, the cumulative extensions granted under the Development Cure Period (other than the extensions granted pursuant to clause 4(d) above) shall not exceed for any reason, including a Force Majeure Event; provided, however, that Seller shall be allowed additional day-for-day extensions beyond the not to exceed a total of cumulative extensions granted under Sections 4(a), 4(b) and 4(c) under the Development Cure Period of solely to the extent due to a Force Majeure Event related to COVID-19. The cumulative extensions granted to the Guaranteed Commercial Operation Date by the payment of Commercial Operation Delay Damages and any Development Cure Period(s) (other than the extensions granted pursuant to clause 4(d) above) shall not exceed (if the maximum Commercial Operation Delay Damages are paid), which may be extended up to if the Development Cure Period is extended up to due to a Force Majeure Event related to COVID-19. Upon request from Buyer, Seller shall provide Exhibit B - 3
documentation demonstrating to Buyer’s reasonable satisfaction that the delays described above did not result from Seller’s actions or failure to take commercially reasonable actions.

5. Failure to Reach Guaranteed PV Capacity or Guaranteed Storage Capacity. a. Guaranteed PV Capacity. If, at Commercial Operation, the Installed PV Capacity is less than one hundred percent (100%) of the Guaranteed PV Capacity, Seller shall have ninety (90) days after the Commercial Operation Date to install additional capacity and/or Network Upgrades such that the Installed PV Capacity is equal to (but not greater than) the Guaranteed PV Capacity, and Seller shall provide to Buyer a new certificate substantially in the form attached as Exhibit I-1 hereto specifying the new Installed PV Capacity. If Seller fails to construct the Guaranteed PV Capacity by such date, Seller shall pay “PV Capacity Damages” to Buyer, in an amount equal to
for each MW that the Guaranteed PV Capacity exceeds the Installed PV Capacity, and the applicable portions of the Agreement shall be adjusted accordingly consistent with the Installed PV Capacity.
b. Guaranteed Storage Capacity. If, at Commercial Operation, the Installed Storage Capacity is less than one hundred percent (100%) of the Guaranteed Storage Capacity, Seller shall have ninety (90) days after the Commercial Operation Date to install additional capacity and/or Network Upgrades such that the Installed Storage Capacity is equal to (but not greater than) one hundred percent (100%) of the Guaranteed Storage Capacity, and Seller shall provide to Buyer a new certificate substantially in the form attached as Exhibit I-1 hereto specifying the new Installed Storage Capacity. If Seller fails to construct the Guaranteed Storage Capacity by such date, Seller shall pay “Storage Capacity Damages” to Buyer, in an amount equal to for each MW at four
hours of continuous discharge that the Guaranteed Storage Capacity exceeds the Installed Storage Capacity, and the applicable portions of the Agreement shall be adjusted accordingly consistent with the Installed Storage Capacity.

Capacity Damages shall not be offset or reduced by the payment of Development Security, Performance Security, Delay Damages, or any other form of liquidated damages under this Agreement.

6. Buyer’s Right to Draw on Development Security. If Seller fails to timely pay any Daily Delay Damages or Commercial Operation Delay Damages, Buyer may draw upon the Development Security to satisfy Seller’s payment obligation thereof.

Exhibit C - 1

EXHIBIT C

COMPENSATION
Buyer shall compensate Seller for the Product in accordance with this Exhibit C. (a) Renewable Rate. Buyer shall pay Seller the Renewable Rate for each MWh of PV Energy, plus Deemed Delivered Energy, if any, up to of the Expected Energy for such Contract Year.
(b) Excess Contract Year Deliveries. Notwithstanding the foregoing, if at any point in any Contract Year, the amount of PV Energy plus Deemed Delivered Energy exceeds of the Expected Energy for such Contract Year, the price to be paid for additional PV Energy and/or Deemed Delivered Energy shall be (c) Excess Settlement Interval Deliveries. If during any Settlement Interval, Seller delivers PV Energy in excess of the product of the Guaranteed PV Capacity and the duration of the Settlement Interval, expressed in hours (“Excess MWh”), then the price applicable to all such Excess MWh in such Settlement Interval shall be zero dollars ($0), and if there is a Negative LMP during such Settlement Interval, Seller shall pay to Buyer an amount equal to the absolute value of the Negative LMP times such Excess MWh.
(d) Monthly Capacity Payment.
(i) Each month of the Delivery Term (and pro-rated for the first and last month of the Delivery Term if the Delivery Term does not start on the first day of a calendar month), Buyer shall pay Seller a Monthly Capacity Payment equal to the Storage Rate x Effective Storage Capacity. Such payment constitutes the entirety of the amount due to Seller from Buyer for the Storage Product. If the Effective Storage Capacity is adjusted pursuant to a Storage Capacity Test other than the first day of calendar month, payment shall be calculated separately for each portion of the month in which the different Effective Storage Capacity is applicable. (ii) Storage Capacity Availability Payment True-Up. Each month during the Delivery Term, Buyer shall calculate the year-to-date (YTD) Annual Storage Capacity Availability for the applicable Contract Year in accordance with Exhibit P. If (A) such YTD Annual Storage Capacity Availability is less than ninety percent (90%), or (B) the final Annual Storage Capacity Availability is less than the Guaranteed Storage Availability, Buyer shall (1) withhold the Storage Capacity Availability Payment True-Up Amount from the next Monthly Capacity Payment(s) (the “Storage Capacity Availability Payment True-Up”), and (2) provide Seller with a written statement of the calculation of the YTD Annual Storage Capacity Availability and the Storage Capacity Availability Payment True-Up Amount; provided, if the Storage Capacity Availability Payment True-Up Amount is a negative number for any month prior to the final year-end Storage Capacity Availability Payment True-Up calculation, Buyer shall not be obligated to reimburse Seller any previously withheld Storage Capacity Availability Payment True-Up Amount, except as set forth in the following sentence. If Buyer withholds any Storage Capacity Availability Payment True-Up Amount pursuant to this subsection (d)(ii), and if the final year-end Storage Capacity Availability Payment True-Up Amount is a negative number, Buyer shall pay to Seller the positive value of such amount together with the next Monthly Capacity Payment due to Seller.

Exhibit C - 2
36370680v5
“Storage Capacity Availability Payment True-Up Amount” means an amount equal to A x B - C, where:

A = The sum of the year-to-date Monthly Capacity Payments B = The Capacity Availability Factor
C = The sum of any Storage Capacity Availability Payment True-Up Amounts previously withheld by Buyer in the applicable Contract Year. “Capacity Availability Factor” means:
(A) If the YTD Annual Storage Capacity Availability times the Effective Storage Capacity is equal to or greater than the Guaranteed Storage Availability times the Effective Storage Capacity, then:

Capacity Availability Factor = 0
(B) If the YTD Annual Storage Capacity Availability times the Effective Storage Capacity is less than the Guaranteed Storage Availability times the Effective Storage Capacity, but greater than or equal to of the
Installed Storage Capacity, then:

Capacity Availability Factor = Guaranteed Storage Availability – YTD Annual Storage Capacity Availability
(C) If the YTD Annual Storage Capacity Availability times the Effective Storage Capacity is less than of the Installed Storage Capacity, then:

Capacity Availability Factor =
provided that, if the result of any of the calculations in clauses (A) through (C) above is greater than 1.0, then the Capacity Availability Factor shall be deemed to be equal to 1.0. (e) Test Energy. Test Energy is compensated in accordance with Section 3.6.

Liquidated Damages for Failure to Achieve Guaranteed Efficiency Rate. (g) Tax Credits. The Parties agree that the neither the Renewable Rate, the Storage Rate nor the Test Energy Rate are subject to adjustment or amendment if Seller fails to receive any Tax Credits, or if any Tax Credits expire, are repealed or otherwise cease to apply to Seller or the Exhibit C - 3
36370680v5
Facility in whole or in part, or Seller or its investors are unable to benefit from any Tax Credits.

Seller shall bear all risks, financial and otherwise, throughout the Contract Term, associated with Seller’s or the Facility’s eligibility to receive Tax Credits or to qualify for accelerated depreciation for Seller’s accounting, reporting or Tax purposes. The obligations of the Parties hereunder, including those obligations set forth herein regarding the purchase and price for and Seller’s obligation to deliver Facility Energy and Product, shall be effective regardless of whether construction of the Facility (or any portion thereof) or the sale of Facility Energy is eligible for, or receives Tax Credits during the Contract Term.

Exhibit D - 1

EXHIBIT D

SCHEDULING COORDINATOR RESPONSIBILITIES
Scheduling Coordinator Responsibilities.
(i) Buyer as Scheduling Coordinator for the Facility. Upon Initial Synchronization of the Facility to the CAISO Grid, Buyer shall be the Scheduling Coordinator or designate a qualified third party to provide Scheduling Coordinator services with the CAISO for the Facility for both the delivery and the receipt of Test Energy and the Product at the Delivery Point. At least thirty (30) days prior to the Initial Synchronization of the Facility to the CAISO Grid, (i) Seller shall take all actions and execute and deliver to Buyer and the CAISO all documents necessary to authorize or designate Buyer (or Buyer’s designee) as the Scheduling Coordinator for the Facility effective as of the Initial Synchronization of the Facility to the CAISO Grid, and (ii) Buyer shall, and shall cause its designee to, take all actions and execute and deliver to Seller and the CAISO all documents necessary to authorize or designate Buyer or its designee as the Scheduling Coordinator for the Facility effective as of the Initial Synchronization of the Facility to the CAISO Grid. On and after Initial Synchronization of the Facility to the CAISO Grid, Seller shall not authorize or designate any other party to act as the Facility’s Scheduling Coordinator, nor shall Seller perform for its own benefit the duties of Scheduling Coordinator, and Seller shall not revoke Buyer’s authorization to act as the Facility’s Scheduling Coordinator unless agreed to by Buyer. Buyer (as the Facility’s SC) shall submit bids to the CAISO in accordance with this Agreement and the applicable CAISO Tariff, protocols and Scheduling practices for Product on a day-ahead, hour-ahead, fifteen-minute market, real-time or other market basis that may develop after the Effective Date, as determined by Buyer.
(ii) Notices. Buyer (as the Facility’s SC) shall provide Seller with access to a web-based system through which Seller shall submit to Buyer and the CAISO all notices and updates required under the CAISO Tariff regarding the Facility’s status, including, but not limited to, all outage requests, forced outages, forced outage reports, clearance requests, or must offer waiver forms. Seller will cooperate with Buyer to provide such notices and updates. If the web-based system is not available, Seller shall promptly submit such information to Buyer and the CAISO by (in order of preference) telephonically or electronic mail to the personnel designated to receive such information.
(iii) CAISO Costs and Revenues. Except as otherwise set forth below, Buyer (as Scheduling Coordinator for the Facility) shall be responsible for CAISO costs (including penalties, Imbalance Energy costs or revenues, and other charges) and shall be entitled to all CAISO revenues (including credits, Imbalance Energy revenues or costs, and other payments), including revenues associated with CAISO dispatches, bid cost recovery, Inter-SC Trade credits, or other credits in respect of the Product Scheduled or delivered from the Facility. Seller shall be responsible for all CAISO penalties resulting from any failure by Seller to abide by the CAISO Tariff or the outage notification requirements set forth in this Agreement (except to the extent such non-compliance is caused by Buyer’s failure to perform its duties as Scheduling Coordinator for the Facility). The Parties agree that any Availability Incentive Payments (as defined in the CAISO Tariff) are for the benefit of Seller and for Seller’s account and that any Non-Availability Charges (as defined in the CAISO Tariff) are the responsibility of Seller and for Seller’s account. In addition, if during the Delivery Term, the CAISO implements or has implemented any sanction or Exhibit D - 2
penalty related to scheduling, outage reporting, or generator operation, and any such sanctions or penalties are imposed upon the Facility or to Buyer as Scheduling Coordinator due to failure by Seller to abide by the CAISO Tariff or the outage notification requirements set forth in this Agreement, the cost of the sanctions or penalties shall be Seller’s responsibility. (iv) CAISO Settlements. Buyer (as the Facility’s SC) shall be responsible for all settlement functions with the CAISO related to the Facility. Buyer shall render a separate invoice to Seller for any CAISO payments, charges or penalties (“CAISO Charges Invoice”) for which Seller is responsible under this Agreement. CAISO Charges Invoices shall be rendered after settlement information becomes available from the CAISO that identifies any CAISO charges.

Notwithstanding the foregoing, Seller acknowledges that the CAISO will issue additional invoices reflecting CAISO adjustments to such CAISO charges. Buyer will review, validate, and if requested by Seller under paragraph (e) below, dispute any charges that are the responsibility of Seller in a timely manner and consistent with Buyer’s existing settlement processes for charges that are Buyer’s responsibilities. Subject to Seller’s right to dispute and to have Buyer pursue the dispute of any such invoices, Seller shall pay the amount of CAISO Charges Invoices within ten (10) Business Days of Seller’s receipt of the CAISO Charges Invoice. If Seller fails to pay such CAISO Charges Invoice within that period, Buyer may net or offset any amounts owing to it for such CAISO Charges Invoices against any future amounts it may owe to Seller under this Agreement. The obligations under this Section with respect to payment of CAISO Charges Invoices shall survive the expiration or termination of this Agreement. (v) Dispute Costs. Buyer (as the Facility’s SC) may be required by Seller to dispute CAISO settlements in respect of the Facility. Seller agrees to pay Buyer’s costs and expenses (including reasonable attorneys’ fees) associated with its involvement with such CAISO disputes to the extent they relate to CAISO charges payable by Seller with respect to the Facility that Seller has directed Buyer to dispute.
(vi) Terminating Buyer’s Designation as Scheduling Coordinator. At least thirty (30) days prior to expiration of this Agreement or as soon as reasonably practicable upon an earlier termination of this Agreement, the Parties will take all actions necessary to terminate the designation of Buyer as Scheduling Coordinator for the Facility as of 11:59 p.m. on such expiration date.
(vii) Master Data File and Resource Data Template. Seller shall provide the data to the CAISO (and to Buyer) that is required for the CAISO’s Master Data File and Resource Data Template (or successor data systems) for the Facility consistent with this Agreement. Neither Party shall change such data without the other Party’s prior written consent. (viii) NERC Reliability Standards. Buyer (as Scheduling Coordinator) shall cooperate reasonably with Seller to the extent necessary to enable Seller to comply, and for Seller to demonstrate Seller’s compliance with, NERC reliability standards. This cooperation shall include the provision of information in Buyer’s possession that Buyer (as Scheduling Coordinator) has provided to the CAISO related to the Facility or actions taken by Buyer (as Scheduling Coordinator) related to Seller’s compliance with NERC reliability standards.

Exhibit E - 1

EXHIBIT E

PROGRESS REPORTING FORM
Each Progress Report must include the following items:

1. Executive Summary.

2. Facility description.

3. Site plan of the Facility.

4. Description of any material planned changes to the Facility or the Site.

5. Gantt chart schedule showing progress on achieving each of the Milestones.

6. Summary of activities during the previous calendar quarter or month, as applicable, including any OSHA labor hour reports.

7. Forecast of activities scheduled for the current calendar quarter.

8. Written description about the progress relative to Seller’s Milestones, including whether Seller has met or is on target to meet the Milestones.

9. List of issues that are reasonably likely to affect Seller’s Milestones.

10. A status report of start-up activities including a forecast of activities ongoing and after start-up, a report on Facility performance including performance projections for the next twelve (12) months.

11. Progress and schedule of all material agreements, contracts, permits, approvals, technical studies, financing agreements and major equipment purchase orders showing the start dates, completion dates, and completion percentages.

12. Pictures, in sufficient quantity and of appropriate detail, in order to document construction and startup progress of the Facility, the interconnection into the Transmission System and all other interconnection utility services.

13. Workforce Development or Supplier Diversity Reporting (if applicable). Format to be provided by Buyer.

14. Any other documentation reasonably requested by Buyer.

Exhibit F-1
EXHIBIT F-1

MONTHLY EXPECTED AVAILABLE GENERATING FACILITY CAPACITY [MW Per Hour] – [Insert Month]
1:00 2:00 3:00 4:00 5:00 6:00 7:00 8:00 9:00 10:00 11:00 12:00 13:00 14:00 15:00 16:00 17:00 18:00 19:00 20:00 21:00 22:00 23:00 24:00 JAN
FEB
MAR
APR
MAY
JUN
JUL
AUG
SEP
OCT
NOV
DEC
The foregoing table is provided for informational purposes only, and it shall not constitute, or be deemed to constitute, an obligation of any of the Parties to this Agreement.

Exhibit F-2
EXHIBIT F-2

MONTHLY EXPECTED PV ENERGY
[MWh Per Hour] – [Insert Month]
1:00 2:00 3:00 4:00 5:00 6:00 7:00 8:00 9:00 10:00 11:00 12:00 13:00 14:00 15:00 16:00 17:00 18:00 19:00 20:00 21:00 22:00 23:00 24:00 JAN
FEB
MAR
APR
MAY
JUN
JUL
AUG
SEP
OCT
NOV
DEC
The foregoing table is provided for informational purposes only, and it shall not constitute, or be deemed to constitute, an obligation of any of the Parties to this Agreement.

Exhibit F-3
EXHIBIT F-3

MONTHLY EXPECTED AVAILABLE EFFECTIVE STORAGE CAPACITY
[MW Per Hour] – [Insert Month]
1:00 2:00 3:00 4:00 5:00 6:00 7:00 8:00 9:00 10:00 11:00 12:00 13:00 14:00 15:00 16:00 17:00 18:00 19:00 20:00 21:00 22:00 23:00 24:00 JAN
FEB
MAR
APR
MAY
JUN
JUL
AUG
SEP
OCT
NOV
DEC
The foregoing table is provided for informational purposes only, and it shall not constitute, or be deemed to constitute, an obligation of any of the Parties to this Agreement.

Exhibit F-4
EXHIBIT F-4

MONTHLY AVAILABLE STORAGE CAPABILITY
[MWh Per Hour] – [Insert Month]
1:00 2:00 3:00 4:00 5:00 6:00 7:00 8:00 9:00 10:00 11:00 12:00 13:00 14:00 15:00 16:00 17:00 18:00 19:00 20:00 21:00 22:00 23:00 24:00 Day 1
Day 2
Day 3
Day 4
Day 5
[insert additional rows for each day in the month]
Day
29 Day
30 Day
31 The foregoing table is provided for informational purposes only, and it shall not constitute, or be deemed to constitute, an obligation of any of the Parties to this Agreement.

Exhibit G - 1

EXHIBIT G

GUARANTEED ENERGY PRODUCTION DAMAGES CALCULATION
In accordance with Section 4.7, if Seller fails to achieve the Guaranteed Energy Production during any Performance Measurement Period, a liquidated damages payment shall be due from Seller to Buyer, calculated as follows:
[(A – B) * (C – D)]
where:

A = the Guaranteed Energy Production amount for the Performance Measurement Period, in MWh
B = the Adjusted Energy Production amount for the Performance Measurement Period, in MWh
C =
D = the Renewable Rate, in $/MWh
“Adjusted Energy Production” shall mean the sum of the following: PV Energy + Deemed Delivered Energy + Lost Output + Replacement Product. “Replacement Energy” means energy produced by a facility other than the Facility, that is provided by Seller to Buyer as Replacement Product, in an amount equal to the amount of Replacement Green Attributes provided by Seller as Replacement Product for the same Performance Measurement Period.
“Replacement Green Attributes” means PCC1 Renewable Energy Credits with the same year of production as the Renewable Energy Credits that would have been generated by the Facility.
“Replacement Product” means (a) Replacement Energy, and (b) Replacement Green Attributes in an amount not to exceed ten percent (10%) of the Expected Energy for the previous Contract Year.

No payment shall be due if the calculation of (A - B) or (C - D) yields a negative number.

Within sixty (60) days after each Contract Year, Buyer will send Seller Notice of the amount of damages owing, if any, which shall be payable to Buyer before the later of (a) thirty (30) days of such Notice and (b) ninety (90) days after each Performance Measurement Period, Exhibit G - 2
provided that the amount of damages owing shall be adjusted to account for Replacement Product, if any, delivered after each applicable Performance Measurement Period.

Exhibit H - 1

EXHIBIT H

FORM OF COMMERCIAL OPERATION DATE CERTIFICATE
This certification (“Certification”) of Commercial Operation is delivered by _______[licensed professional engineer] (“Engineer”) to Valley Clean Energy Alliance, a California joint powers authority (“Buyer”) in accordance with the terms of that certain Renewable Power Purchase Agreement dated _______ (“Agreement”) by and between [Seller] and Buyer. All capitalized terms used in this Certification but not otherwise defined herein shall have the respective meanings assigned to such terms in the Agreement.

As of _______[DATE]_____, Engineer hereby certifies and represents to Buyer the following:

1. The Generating Facility is fully operational, reliable and interconnected, fully integrated and synchronized with the Transmission System.

2. Seller has installed equipment for the Generating Facility with an Installed PV Capacity of no less than ninety-five percent (95%) of the Guaranteed PV Capacity.

3. Seller has installed equipment for the Storage Facility with an Installed Storage Capacity of no less than ninety-five percent (95%) of the Guaranteed Storage Capacity.

4. Authorization to parallel the Facility was obtained by the Transmission Provider, [Name of Transmission Provider as appropriate] on___[DATE]____.

5. The Transmission Provider has provided documentation supporting full unrestricted release for Commercial Operation by [Name of Transmission Provider as appropriate] on _______[DATE]_____.

6. The CAISO has provided notification supporting Commercial Operation, in accordance with the CAISO Tariff on _______[DATE]_____.

EXECUTED by [LICENSED PROFESSIONAL ENGINEER]
this ________ day of _____________, 20__.
[LICENSED PROFESSIONAL ENGINEER]
By:

Its:

Date:

Exhibit I - 1
EXHIBIT I-1

FORM OF INSTALLED CAPACITY CERTIFICATE
This certification (“Certification”) of Installed Capacity and related characteristics of the Facility is delivered by [licensed professional engineer] (“Engineer”) to Valley Clean Energy Alliance, a California joint powers authority (“Buyer”) in accordance with the terms of that certain Renewable Power Purchase Agreement dated __________ (“Agreement”) by and between [SELLER ENTITY] and Buyer. All capitalized terms used in this Certification but not otherwise defined herein shall have the respective meanings assigned to such terms in the Agreement.

I hereby certify the following:
(a) The installed nameplate capacity of the Generating Facility is __ MW AC (“Installed PV Capacity”);
(b) The Commercial Operation Storage Capacity Test demonstrated a maximum dependable operating capability to discharge electric energy of __ MW AC to the Delivery Point at four (4) hours of continuous discharge, in accordance with the testing procedures, requirements and protocols set forth in Section 4.9 and Exhibit O (the “Installed Storage Capacity”);
(c) The sum of (a) and (b) is __ MW AC and shall be the “Installed Capacity”; and
(d) The Commercial Operation Storage Capacity Test demonstrated (i) a Battery Charging Factor of __%, and (ii) a Battery Discharging Factor of __%, each in accordance with the testing procedures, requirements and protocols set forth in Section 4.9 and Exhibit O.

EXECUTED by [LICENSED PROFESSIONAL ENGINEER]
this ________ day of _____________, 20__.
[LICENSED PROFESSIONAL ENGINEER]
By:

Its:

Date:

Exhibit I - 2
EXHIBIT I-2

FORM OF EFFECTIVE STORAGE CAPACITY CERTIFICATE
This certification (“Certification”) of Effective Storage Capacity and related characteristics of the Facility is delivered by [licensed professional engineer] (“Engineer”) to Valley Clean Energy Alliance, a California joint powers authority (“Buyer”) in accordance with the terms of that certain Renewable Power Purchase Agreement dated __________ (“Agreement”) by and between [SELLER ENTITY] and Buyer. All capitalized terms used in this Certification but not otherwise defined herein shall have the respective meanings assigned to such terms in the Agreement.

I hereby certify the following:
(a) The Storage Capacity Test demonstrated a maximum dependable operating capability to discharge electric energy of __ MW AC to the Delivery Point at four (4) hours of continuous discharge, in accordance with the testing procedures, requirements and protocols set forth in Section 4.9 and Exhibit O of the Agreement (the “Effective Storage Capacity”); and (b) The Storage Capacity Test demonstrated (i) a Battery Charging Factor of __%, and (ii) a Battery Discharging Factor of __%, each in accordance with the testing procedures, requirements and protocols set forth in Section 4.9 and Exhibit O.

EXECUTED by [LICENSED PROFESSIONAL ENGINEER]
this ________ day of _____________, 20__.
[LICENSED PROFESSIONAL ENGINEER]
By:

Its:

Date:

Exhibit J - 1

EXHIBIT J

FORM OF CONSTRUCTION START DATE CERTIFICATE
This certification of Construction Start Date (“Certification”) is delivered by [SELLER ENTITY] (“Seller”) to Valley Clean Energy Alliance, a California joint powers authority (“Buyer”) in accordance with the terms of that certain Renewable Power Purchase Agreement dated __________ (“Agreement”) by and between Seller and Buyer. All capitalized terms used in this Certification but not otherwise defined herein shall have the respective meanings assigned to such terms in the Agreement.

Seller hereby certifies and represents to Buyer the following:
(1) Construction Start (as defined in Exhibit B of the Agreement) has occurred, and a copy of the notice to proceed that Seller issued to its contractor as part of Construction Start is attached hereto.
(2) the Construction Start Date occurred on _____________ (the “Construction Start Date”); and
(3) the precise Site on which the Facility is located is, which must be within the boundaries of the previously identified Site:
_____________________________________________________________________ (such description shall amend the description of the Site in Exhibit A of the Agreement).

IN WITNESS WHEREOF, the undersigned has executed this Certification on behalf of Seller as of the ___ day of ________.
[SELLER ENTITY]
By:

Its:

Date:

Exhibit K - 1

EXHIBIT K

FORM OF LETTER OF CREDIT
[Issuing Bank Letterhead and Address]
IRREVOCABLE STANDBY LETTER OF CREDIT NO. [XXXXXXX]
Date:

Bank Ref.:

Amount: US$[XXXXXXXX]
Expiry Date:

APPLICANT DETAILS TO BE PROVIDED
Beneficiary:

Valley Clean Energy Alliance, a California joint powers authority [Address]
Ladies and Gentlemen:

By the order of __________ (“Applicant”), we, [insert bank name and address] (“Issuer”) hereby issue our Irrevocable Standby Letter of Credit No. [XXXXXXX] (the “Letter of Credit”) in favor of Valley Clean Energy Alliance, a California joint powers authority (“Beneficiary”), [Address], for an amount not to exceed the aggregate sum of U.S. $[XXXXXX] (United States Dollars [XXXXX] and 00/100), pursuant to that certain Agreement dated as of___________ and as amended (the “Agreement”) between [Applicant] and Beneficiary. This Letter of Credit shall become effective immediately and shall expire on [XXXXXX] which is one year after the issue date of this Letter of Credit, or any expiration date extended in accordance with the terms hereof (the “Expiration Date”).

Funds under this Letter of Credit are available to Beneficiary by presentation on or before the Expiration Date of a dated statement purportedly signed by your duly authorized representative, in the form attached hereto as Exhibit A, containing one of the two alternative paragraphs set forth in paragraph 2 therein, referencing our Letter of Credit No. [XXXXXXX] (“Drawing Certificate”).

The Drawing Certificate may be presented by (a) physical delivery, or (b) facsimile to [bank fax number [XXX-XXX-XXXX]] confirmed by [e-mail to [bank email address]] (if presented by fax it must be followed up by a phone call to us at [XXXXXX] or [XXXXXX] to confirm receipt)with the originals to follow via courier. The drawing will be effective upon our receipt of the original documents at the above noted address.

Exhibit K - 2
The original of this Letter of Credit (and all amendments, if any) is not required to be presented in connection with any presentment of a Drawing Certificate by Beneficiary hereunder in order to receive payment.

We hereby agree with the Beneficiary that documents presented under and in compliance with the terms of this Letter of Credit will be duly honored upon presentation to the Issuer on or before the Expiration Date. All payments made under this Letter of Credit shall be made with Issuer’s own immediately available funds by means of wire transfer in immediately available United States dollars to Beneficiary’s account as indicated by Beneficiary in its Drawing Certificate or in a communication accompanying its Drawing Certificate.

Partial draws are permitted under this Letter of Credit, and this Letter of Credit shall remain in full force and effect with respect to any continuing balance.

It is a condition of this Letter of Credit that the Expiration Date shall be deemed automatically extended without an amendment for a one year period beginning on the present Expiration Date hereof and upon each anniversary for such date, unless at least one hundred twenty (120) days prior to any such Expiration Date we have sent to you written notice by registered mail or overnight courier service that we elect not to extend this Letter of Credit, in which case it will expire on the date specified in such notice. No presentation made under this Letter of Credit after such Expiration Date will be honored.

Notwithstanding any reference in this Letter of Credit to any other documents, instruments or agreements, this Letter of Credit contains the entire agreement between Beneficiary and Issuer relating to the obligations of Issuer hereunder.

This Letter of Credit is subject to the Uniform Customs and Practice for Documentary Credits (2007 Revision) International Chamber of Commerce Publication No. 600 (the “UCP”), except to the extent that the terms hereof are inconsistent with the provisions of the UCP, including but not limited to Articles 14(b) and 36 of the UCP, in which case the terms of this Letter of Credit shall govern. In the event of an act of God, riot, civil commotion, insurrection, war or any other cause beyond Issuer’s control (as defined in Article 36 of the UCP) that interrupts Issuer’s business and causes the place for presentation of the Letter of Credit to be closed for business on the last day for presentation, the Expiration Date of the Letter of Credit will be automatically extended without amendment to a date thirty (30) calendar days after the place for presentation reopens for business.

Please address all correspondence regarding this Letter of Credit to the attention of the Letter of Credit Department at [insert bank address information], referring specifically to Issuer’s Letter of Credit No. [XXXXXXX]. For telephone assistance, please contact Issuer’s Standby Letter of Credit Department at [XXX-XXX-XXXX] and have this Letter of Credit available.

All notices to Beneficiary shall be in writing and are required to be sent by certified letter, overnight courier, or delivered in person to: Valley Clean Energy Alliance, Chief Operating Officer, [Address]. Only notices to Beneficiary meeting the requirements of this paragraph shall be considered valid. Any notice to Beneficiary which is not in accordance with this paragraph shall be void and of no force or effect.

Exhibit K - 3
[Bank Name]
___________________________
[Insert officer name]
[Insert officer title]
Exhibit K - 4
Exhibit A: (DRAW REQUEST SHOULD BE ON BENEFICIARY’S LETTERHEAD) Drawing Certificate
[Insert Bank Name and Address]
Ladies and Gentlemen:

The undersigned, a duly authorized representative of Valley Clean Energy Alliance, a California joint powers authority, [Buyer address], as beneficiary (the “Beneficiary”) of the Irrevocable Letter of Credit No. [XXXXXXX] (the “Letter of Credit”) issued by [insert bank name] (the “Bank”) by order of __________ (the “Applicant”), hereby certifies to the Bank as follows:

1. Applicant and Beneficiary are party to that certain Agreement dated as of ___________, (the “Agreement”).

2. Beneficiary is making a drawing under this Letter of Credit in the amount of U.S. $___________ because a Seller Event of Default (as such term is defined in the Agreement) or other occasion provided for in the Agreement where Beneficiary is authorized to draw on the letter of credit has occurred.

OR
Beneficiary is making a drawing under this Letter of Credit in the amount of U.S. $___________, which equals the full available amount under the Letter of Credit, because we have received notice from the Bank that you have elected not to extend the Expiration Date of the Letter of Credit beyond its current Expiration Date and Applicant is required to maintain the Letter of Credit in force and effect beyond the expiration date of the Letter of Credit but has failed to provide Beneficiary with a replacement Letter of Credit or other acceptable instrument within thirty (30) days prior to such expiration date.

3. The undersigned is a duly authorized representative of Valley Clean Energy Alliance, a California joint powers authority and is authorized to execute and deliver this Drawing Certificate on behalf of Beneficiary.

You are hereby directed to make payment of the requested amount to Valley Clean Energy Alliance, a California joint powers authority by wire transfer in immediately available funds to the following account:
[Specify account information]
Valley Clean Energy Alliance
_______________________________
Name and Title of Authorized Representative
Date___________________________
Exhibit L - 1

EXHIBIT L

FORM OF GUARANTY
THIS GUARANTY (this “Guaranty”), dated as of _____, ____ (the “Effective Date”), is made by (“Guarantor”), in favor of
[__________________________] (“Counterparty”).

RECITALS:

A. WHEREAS, Counterparty and Guarantor’s indirect, wholly-owned subsidiary [____________________________] (“Obligor”) have entered into, or concurrently herewith are entering into, that certain [Insert Name of Agreement] [dated/made/entered into/effective as of] ______, 20__ (the “Agreement”); and B. WHEREAS, Guarantor will directly or indirectly benefit from the Agreement between Obligor and Counterparty;
NOW THEREFORE, in consideration of the foregoing premises and as an inducement for Counterparty’s execution, delivery and performance of the Agreement, and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, Guarantor hereby agrees for the benefit of Counterparty as follows:
* * *

1. GUARANTY. Subject to the terms and provisions hereof, Guarantor hereby absolutely and irrevocably guarantees the timely payment when due of all obligations owing by Obligor to Counterparty arising pursuant to the Agreement on or after the Effective Date (the “Obligations”).

This Guaranty shall constitute a guarantee of payment and not of collection. The liability of Guarantor under this Guaranty shall be subject to the following limitations:
(a) Notwithstanding anything herein or in the Agreement to the contrary, the maximum aggregate obligation and liability of Guarantor under this Guaranty, and the maximum recovery from Guarantor under this Guaranty, shall in no event exceed __________________ [spell out the dollar amount] U.S. Dollars (U.S. $__________) (the “Maximum Recovery Amount”).
(b) The obligation and liability of Guarantor under this Guaranty is specifically limited to payments expressly required to be made under the Agreement, as well as costs of collection and enforcement of this Guaranty (including attorney’s fees) to the extent reasonably and actually incurred by the Counterparty (subject in all instances, to the limitations imposed by the Maximum Recovery Amount as specified in Section 1(a) above). In no event, however, shall Guarantor be liable for or obligated to pay any consequential, indirect, incidental, lost profit, special, exemplary, punitive, equitable or tort damages, unless such damages are owed by Obligor to Counterparty pursuant to the Agreement.

2. DEMANDS AND PAYMENT.

Exhibit L - 2
(a) If Obligor fails to pay any Obligation to Counterparty when such Obligation is due and owing under the Agreement (an “Overdue Obligation”), Counterparty may present a written demand to Guarantor calling for Guarantor’s payment of such Overdue Obligation pursuant to this Guaranty (a “Payment Demand”).
(b) Guarantor’s obligation hereunder to pay any particular Overdue Obligation(s) to Counterparty is conditioned upon Guarantor’s receipt of a Payment Demand from Counterparty satisfying the following requirements: (i) such Payment Demand must identify the specific Overdue Obligation(s) covered by such demand, the specific date(s) upon which such Overdue Obligation(s) became due and owing under the Agreement, and the specific provision(s) of the Agreement pursuant to which such Overdue Obligation(s) became due and owing; (ii) such Payment Demand must be delivered to Guarantor in accordance with Section 9 below; and (iii) the specific Overdue Obligation(s) addressed by such Payment Demand must remain due and unpaid at the time of such delivery to Guarantor.
(c) After issuing a Payment Demand in accordance with the requirements specified in Section 2(b) above, Counterparty shall not be required to issue any further notices or make any further demands with respect to the Overdue Obligation(s) specified in that Payment Demand, and Guarantor shall be required to make payment with respect to the Overdue Obligation(s) specified in that Payment Demand within five (5) Business Days after Guarantor receives such demand. As used herein, the term “Business Day” shall mean all weekdays (i.e., Monday through Friday) other than any weekdays during which commercial banks or financial institutions are authorized to be closed to the public in the State of Florida or the State of New York.

3. REPRESENTATIONS AND WARRANTIES. Guarantor represents and warrants that:
(a) it is a corporation duly organized and validly existing under the laws of the State of Florida and has the corporate power and authority to execute, deliver and carry out the terms and provisions of the Guaranty;
(b) no authorization, approval, consent or order of, or registration or filing with, any court or other governmental body having jurisdiction over Guarantor is required on the part of Guarantor for the execution and delivery of this Guaranty; and (c) this Guaranty constitutes a valid and legally binding agreement of Guarantor, enforceable against Guarantor in accordance with the terms hereof, except as the enforceability thereof may be limited by the effect of any applicable bankruptcy, insolvency, reorganization, moratorium or similar laws affecting creditors' rights generally and by general principles of equity.

4. RESERVATION OF CERTAIN DEFENSES. Without limiting Guarantor’s own defenses and rights hereunder, Guarantor reserves to itself all rights, setoffs, counterclaims and other defenses to which Obligor is or may be entitled arising from or out of the Agreement, except for defenses (if any) based upon the bankruptcy, insolvency, dissolution or liquidation of Obligor or any lack of power or authority of Obligor to enter into and/or perform the Agreement.

Exhibit L - 3

5. AMENDMENT OF GUARANTY. No term or provision of this Guaranty shall be amended, modified, altered, waived or supplemented except in a writing signed by Guarantor and Counterparty.

6. WAIVERS AND CONSENTS. Subject to and in accordance with the terms and provisions of this Guaranty:
(a) Except as required in Section 2 above, Guarantor hereby waives (i) notice of acceptance of this Guaranty; (ii) presentment and demand concerning the liabilities of Guarantor; and (iii) any right to require that any action or proceeding be brought against Obligor or any other person, or to require that Counterparty seek enforcement of any performance against Obligor or any other person, prior to any action against Guarantor under the terms hereof. (b) No delay by Counterparty in the exercise of (or failure by Counterparty to exercise) any rights hereunder shall operate as a waiver of such rights, a waiver of any other rights or a release of Guarantor from its obligations hereunder (with the understanding, however, that the foregoing shall not be deemed to constitute a waiver by Guarantor of any rights or defenses which Guarantor may at any time have pursuant to or in connection with any applicable statutes of limitation).
(c) Without notice to or the consent of Guarantor, and without impairing or releasing Guarantor’s obligations under this Guaranty, Counterparty may: (i) change the manner, place or terms for payment of all or any of the Obligations (including renewals, extensions or other alterations of the Obligations); (ii) release any person (other than Obligor or Guarantor) from liability for payment of all or any of the Obligations; or (iii) receive, substitute, surrender, exchange or release any collateral or other security for any or all of the Obligations.

7. REINSTATEMENT. Guarantor agrees that this Guaranty shall continue to be effective or shall be reinstated, as the case may be, if all or any part of any payment made hereunder is at any time avoided or rescinded or must otherwise be restored or repaid by Counterparty as a result of the bankruptcy or insolvency of Obligor, all as though such payments had not been made.

8. TERMINATION. This Guaranty and the Guarantor’s obligations hereunder will terminate automatically and immediately upon the earlier of (i) the termination or expiration of the Agreement or (ii) 11:59:59 Eastern Prevailing Time [_______, _____]; provided, however, that no such termination shall affect Guarantor's liability with respect to any Obligation incurred prior to the time the termination is effective, which Obligation shall remain subject to this Guaranty.

9. NOTICE. Any Payment Demand, notice, request, instruction, correspondence or other document to be given hereunder (herein collectively called “Notice”) by Counterparty to Guarantor, or by Guarantor to Counterparty, as applicable, shall be in writing and may be delivered either by (i) U.S. certified mail with postage prepaid and return receipt requested, or (ii) recognized nationwide courier service with delivery receipt requested, in either case to be delivered to the following address (or to such other U.S. address as may be specified via Notice provided by Guarantor or Counterparty, as applicable, to the other in accordance with the requirements of this Section 9):

Exhibit L - 4
TO GUARANTOR: * TO COUNTERPARTY:

Attn: Treasurer
__________________
__________________
__________________
Attn: _________
[Tel: -- for use in
connection with courier deliveries]
[Tel: (___) ___-___ -- for use in
connection with courier deliveries]
* (NOTE: Copies of any Notices to Guarantor under this Guaranty shall also be sent via facsimile to ATTN: Contracts Group, Legal, Fax No. and ATTN: Credit Department, Fax No. . However, such facsimile transmissions shall not be deemed effective for delivery purposes under this Guaranty.)
Any Notice given in accordance with this Section 9 will (i) if delivered during the recipient's normal business hours on any given Business Day, be deemed received by the designated recipient on such date, and (ii) if not delivered during the recipient's normal business hours on any given Business Day, be deemed received by the designated recipient at the start of the recipient's normal business hours on the next Business Day after such delivery.

10. MISCELLANEOUS.
(a) This Guaranty shall in all respects be governed by, and construed in accordance with, the law of the State of New York, without regard to principles of conflicts of laws thereunder (other than Sections 5-1401 and 5-1402 of the New York General Obligations Law). (b) This Guaranty shall be binding upon Guarantor and its successors and permitted assigns and inure to the benefit of and be enforceable by Counterparty and its successors and permitted assigns. Guarantor may not assign this Guaranty in part or in whole without the prior written consent of Counterparty. Counterparty may not assign its rights or benefits under this Guaranty in part or in whole without the prior written consent of Guarantor. (c) This Guaranty embodies the entire agreement and understanding between Guarantor and Counterparty and supersedes all prior agreements and understandings relating to the subject matter hereof.
(d) The headings in this Guaranty are for purposes of reference only, and shall not affect the meaning hereof. Words importing the singular number hereunder shall include the plural number and vice versa, and any pronouns used herein shall be deemed to cover all genders.

The term "person" as used herein means any individual, corporation, partnership, joint Exhibit L - 5
venture, limited liability company, association, joint-stock company, trust, unincorporated association, or government (or any agency or political subdivision thereof). (e) Wherever possible, any provision in this Guaranty which is prohibited or unenforceable in any jurisdiction shall, as to such jurisdiction, be ineffective only to the extent of such prohibition or unenforceability without invalidating the remaining provisions hereof, and any such prohibition or unenforceability in any one jurisdiction shall not invalidate or render unenforceable such provision in any other jurisdiction. (f) Counterparty (by its acceptance of this Guaranty) and Guarantor each hereby irrevocably:
(i) consents and submits to the exclusive jurisdiction of the United States District Court for the Southern District of New York, or if that court does not have subject matter jurisdiction, to the exclusive jurisdiction of the Supreme Court of the State of New York, New York County (without prejudice to the right of any party to remove to the United States District Court for the Southern District of New York) for the purposes of any suit, action or other proceeding arising out of this Guaranty or the subject matter hereof or any of the transactions contemplated hereby brought by Counterparty, Guarantor or their respective successors or assigns; and (ii) waives (to the fullest extent permitted by applicable law) and agrees not to assert any claim that it is not personally subject to the jurisdiction of the above-named courts, that the suit, action or proceeding is brought in an inconvenient forum, that the venue of the suit, action or proceeding is improper or that this Guaranty or the subject matter hereof may not be enforced in or by such court. (g) COUNTERPARTY (BY ITS ACCEPTANCE OF THIS GUARANTY) AND

GUARANTOR EACH HEREBY IRREVOCABLY, INTENTIONALLY AND

VOLUNTARILY WAIVES THE RIGHT TO TRIAL BY JURY WITH RESPECT TO

ANY LEGAL PROCEEDING BASED ON, OR ARISING OUT OF, UNDER OR IN

CONNECTION WITH, THIS GUARANTY OR THE AGREEMENT, OR ANY

COURSE OF CONDUCT, COURSE OF DEALING, STATEMENTS (WHETHER

VERBAL OR WRITTEN) OR ACTIONS OF ANY PERSON RELATING HERETO OR THERETO. THIS PROVISION IS A MATERIAL INDUCEMENT TO GUARANTOR’S EXECUTION AND DELIVERY OF THIS GUARANTY.
* * *
IN WITNESS WHEREOF, the Guarantor has executed this Guaranty on _____________, 20__, but it is effective as of the Effective Date.

By:

Name:

Title:

Exhibit M - 1

EXHIBIT M

FORM OF REPLACEMENT RA NOTICE
This Replacement RA Notice (this “Notice”) is delivered by [SELLER ENTITY] (“Seller”) to Valley Clean Energy Alliance, a California joint powers authority (“Buyer”) in accordance with the terms of that certain Renewable Power Purchase Agreement dated __________ (“Agreement”) by and between Seller and Buyer. All capitalized terms used in this Notice but not otherwise defined herein shall have the respective meanings assigned to such terms in the Agreement.

Pursuant to Section 3.8 of the Agreement, Seller hereby provides the below Replacement RA product information:

Exhibit M - 2
[SELLER ENTITY]
By:

Its:

Date:

Exhibit N - 1
36370680v5

EXHIBIT N

NOTICES
[SELLER’S NAME]
(“Seller”)

VALLEY CLEAN ENERGY ALLIANCE
(“Buyer”)
All Notices:

Street: 700 Universe Blvd.

City: Juno Beach, FL 33408
Attn: Business Management
Phone:

Email:

All Notices:

Street: 604 2Nd Street
City: Davis, CA 95616
Attn:

Phone:

Email:

Reference Numbers:

Duns:

Federal Tax ID Number:

Reference Numbers:

Duns:

Federal Tax ID Number:

Invoices:

Attn: Business Management
Phone:

E-mail:

Invoices:

Attn:

Phone:

E-mail:

Scheduling:

Attn:

Phone:

Email:

Scheduling:

Attn: Day Ahead Trading, Real Time Trading
Phone:

Email:

Confirmations:

Attn:

Phone:

Email:

Confirmations:

Attn:

Phone:

Email:

Payments:

Attn: Business Management
Phone:

E-mail:

Payments:

Attn:

Phone:

E-mail:

Wire Transfer: Seller shall provide to
Buyer the information below at least 60 days
prior to the Commercial Operation Date.

BNK:

ABA:

ACCT:

Wire Transfer:

BNK:

ABA:

ACCT:

Exhibit O - 1

EXHIBIT O

STORAGE CAPACITY TESTS
Storage Capacity Test Notice and Frequency
A. Commercial Operation Storage Capacity Test(s). Upon no less than ten (10) Business Days prior Notice to Buyer, Seller shall schedule and complete a Commercial Operation Storage Capacity Test prior to the Commercial Operation Date. Such initial Commercial Operation Storage Capacity Test (and any subsequent Commercial Operation Storage Capacity Test permitted in accordance with Exhibit B) shall be performed in accordance with this Exhibit O and shall establish the Installed Storage Capacity hereunder based on the actual capacity and capabilities of the Storage Facility determined by such Commercial Operation Storage Capacity Test(s).

B. Subsequent Storage Capacity Tests. Following the Commercial Operation Storage Capacity Test(s), at least fifteen (15) days in advance of the start of each Contract Year, upon no less than ten (10) Business Days prior Notice to Buyer, Seller shall schedule and complete a Storage Capacity Test. In addition, Buyer shall have the right to require a retest of the Storage Capacity Test at any time upon no less than five (5) Business Days prior written Notice to Seller if Buyer provides data with such Notice reasonably indicating that the then-current Effective Storage Capacity has varied materially from the results of the most recent prior Storage Capacity Test. Seller shall have the right to run a retest of any Storage Capacity Test at any time upon five (5) Business Days’ prior written Notice to Buyer (or any shorter period reasonably acceptable to Buyer consistent with Prudent Operating Practice).

C. Test Results and Re-Setting of Effective Storage Capacity. No later than five (5) days following any Capacity Test, Seller shall submit a testing report detailing results and findings of the test. The report shall include Storage Facility Meter readings and plant log sheets verifying the operating conditions and output of the Storage Facility. In accordance with Section 4.9(a)(ii) of the Agreement and Part II(I) below, after the Commercial Operation Storage Capacity Test(s), the Effective Storage Capacity (up to, but not in excess of, the Installed Storage Capacity) determined pursuant to such Storage Capacity Test shall become the new Effective Storage Capacity at the beginning of the day following the completion of the test for calculating the Contract Price and all other purposes under this Agreement.

Capacity Test Procedures
PART I. GENERAL.
(1) Each Capacity Test shall be conducted in accordance with Prudent Operating Practices, the Operating Restrictions, and the provisions of this Exhibit O. For ease of reference, a Capacity Test is sometimes referred to in this Exhibit O as a “CT”.

Buyer or its representative may be present for the CT and may, for informational purposes only, use its own metering equipment (at Buyer’s sole cost). (2) Conditions Prior to Testing.

Exhibit O - 2
(1) EMS Functionality. The EMS shall be successfully configured to receive data from the Battery Management System (BMS), exchange DNP3 data with the Buyer SCADA device, and transfer data to the database server for the calculation, recording and archiving of data points. (2) Communications. The Remote Terminal Unit (RTU) testing should be successfully completed prior to any testing. The interface between Buyer’s RTU and the Facility SCADA system should be fully tested and functional prior to starting any testing, including verification of the data transmission pathway between the Buyer’s RTU and Seller’s EMS interface and the ability to record SCADA data.
(3) Commissioning Checklist. Commissioning shall be successfully completed per manufacturer guidance on all installed Facility equipment, including verification that all controls, set points, and instruments of the EMS are configured.
(4) Generating Facility Conditions. Any CTs requiring the availability of Charging Energy shall be conducted when the Generating Facility is producing at a rate equal to or above the Effective Storage Capacity continuously for a five (5)-hour period, provided that Seller may waive such conditions at its sole discretion. Any CTs that are required or allowed to occur under this Exhibit O that take place in the absence of the above condition being satisfied shall be subject to a mutually agreed upon adjustment (such agreement not to be unreasonably withheld) between Seller and Buyer with respect to the allowed charging time for such CT and/or the Battery Charging Factor definition, which adjustment(s) shall be commensurate with then-existing irradiance limitations.

PART II. REQUIREMENTS APPLICABLE TO ALL CAPACITY TESTS.

A. Test Elements. Each CT shall include at least the following individual test elements, which must be conducted in the order prescribed in Part III of this Exhibit O, unless the Parties mutually agree to deviations therefrom. The Parties acknowledge and agree that should Seller fall short of demonstrating one or more of the Test Elements as specified below, the Test will still be deemed “complete,” and any adjustments necessary to the Effective Storage Capacity resulting from such Test, if applicable, will be made in accordance with this Exhibit O. (1) Electrical output at maximum discharging level (MW) for four (4) continuous hours; and
(2) Electrical input at maximum charging level at the Storage Facility Meter (MW), as sustained until the SOC reaches at least 90%, continued by the electrical input at a rate up to the maximum charging level at the Storage Facility Meter (MW), as sustained until the SOC reaches 100%, not to exceed five (5) hours of total charging time.

Exhibit O - 3
B. Parameters. During each CT, the following parameters shall be measured and recorded simultaneously for the Storage Facility, at two (2) second intervals:
(1) Time;
(2) The amount of Discharging Energy delivered to the Storage Facility Meter (kWh) (i.e., to each measurement device making up the Storage Facility Meter);
(3) Net electrical energy input from the Storage Facility Meter (kWh) (i.e., from each measurement device making up the Storage Facility Meter); (4) Stored Energy Level (MWh).

C. Site Conditions. During each CT, the following conditions at the Site shall be measured and recorded simultaneously at thirty (30) minute intervals:
(1) Relative humidity (%);
(2) Barometric pressure (inches Hg) near the horizontal centerline of the Storage Facility; and
(3) Ambient air temperature (°F).

D. Test Showing. Each CT shall record and report the following datapoints:
(1) That the CT successfully started;
(2) The maximum sustained discharging level for four (4) consecutive hours pursuant to A(1) above;
(3) The maximum sustained charging level for four (4) consecutive hours pursuant to A(2) above;
(4) Amount of time between the Storage Facility’s electrical output going from 0 to the maximum sustained discharging level registered during the Test (for purposes of calculating the Ramp Rate);
(5) Amount of time between the Storage Facility’s electrical input going from 0 to the maximum sustained charging level registered during the Test (for purposes of calculating the Ramp Rate);
(6) Amount of Charging Energy, registered at the Storage Facility Meter, to go from 0% SOC to 100% SOC;
(7) Amount of Discharging Energy, registered at the Storage Facility Meter, to go from 100% SOC to 0% SOC.

E. Test Conditions.

Exhibit O - 4
(1) General. At all times during a CT, the Storage Facility shall be operated in compliance with Prudent Operating Practices, the Operating Restrictions, and all operating protocols recommended, required or established by the manufacturer for the Storage Facility.
(2) Abnormal Conditions. If abnormal operating conditions that prevent the testing or recordation of any required parameter occur during a CT, Seller may postpone or reschedule all or part of such CT in accordance with Part II.F below.
(3) Instrumentation and Metering. Seller shall provide all instrumentation, metering and data collection equipment required to perform the CT. The instrumentation, metering and data collection equipment electrical meters shall be calibrated in accordance with Prudent Operating Practice and, as applicable, the CAISO Tariff.

F. Incomplete Test. If any CT is not completed in accordance herewith, Buyer may in its sole discretion: (i) accept the results up to the time the CT stopped without any modification to the Effective Storage Capacity pursuant to Section I below; (ii) require that the portion of the CT not completed, be completed within a reasonable specified time period; or (iii) require that the CT be entirely repeated.

Notwithstanding the above, if Seller is unable to complete a CT due to a Force Majeure Event or the actions or inactions of Buyer or the CAISO or the Transmission Provider, Seller shall be permitted to reconduct such CT on dates and at times reasonably acceptable to the Parties.

G. Test Report. Within five (5) Business Days after the completion of any CT, Seller shall prepare and submit to Buyer a written report of the results of the CT, which report shall include:
(1) A record of the personnel present during the CT that served in an operating, testing, monitoring or other such participatory role;
(2) The measured and calculated data for each parameter set forth in Part II.A through D, including copies of the raw data taken during the test; and (3) Seller’s statement of either Seller’s acceptance of the CT or Seller’s rejection of the CT results and reason(s) therefor.

Within five (5) Business Days after receipt of such report, Buyer shall notify Seller in writing of either Buyer’s acceptance of the CT results or Buyer’s rejection of the CT and reason(s) therefor.

If either Party rejects the results of any CT, such CT shall be repeated in accordance with Part II.F.

H. Supplementary Capacity Test Protocol. No later than sixty (60) days prior to commencing Storage Facility construction, Seller shall deliver to Buyer for its Exhibit O - 5
review and approval (such approval not to be unreasonably delayed or withheld) a supplement to this Exhibit O with additional and supplementary details, procedures and requirements applicable to Capacity Tests based on the then-current design of the Storage Facility (“Supplementary Capacity Test Protocol”). Thereafter, from time to time, Seller may deliver to Buyer for its review and approval (such approval not to be unreasonably delayed or withheld) any Seller recommended updates to the then-current Supplementary Capacity Test Protocol. The initial Supplementary Capacity Test Protocol (and each update thereto), once approved by Buyer, shall be deemed an amendment to this Exhibit O.

I. Adjustment to Effective Storage Capacity. The Effective Storage Capacity shall be updated as follows:
(1) The total amount of Discharging Energy delivered to the Delivery Point (expressed in MWh AC) during the first four (4) hours of discharge (up to, but not in excess of, the product of (i) (a) the Guaranteed Storage Capacity (in the case of a Commercial Operation Storage Capacity Test, including under Section 5 of Exhibit B) or (b) the Installed Storage Capacity (in the case of any other Storage Capacity Test), multiplied by (ii) four (4) hours) shall be divided by four (4) hours to determine the Effective Storage Capacity, which shall be expressed in MW AC, and shall be the new Effective Storage Capacity in accordance with Section 4.9(a)(ii) of the Agreement.

PART III. INITIAL SUPPLEMENTARY CAPACITY TEST PROTOCOL.

A. Effective Storage Capacity Test
• Procedure:
(1) System Starting State: The Storage Facility will be in the on-line state at 0% SOC.
(2) Record the initial value of the Storage Facility SOC. (3) Command a real power charge that results in an AC power of Storage Facility’s maximum charging level and continue charging until the earlier of (a) the Storage Facility has reached 100% SOC or (b) five (5) hours have lapsed since the Storage Facility commenced charging.
(4) Record and store the Storage Facility SOC after the earlier of (a) the Storage Facility has reached 100% SOC or (b) five (5) hours of continuous charging.

Such data point shall be used for purposes of calculation of the Battery Charging Factor.
(5) Record and store the AC energy charged to the Storage Facility as measured at the Storage Facility Meter.

Exhibit O - 6
(6) Following an agreed-upon rest period, command a real power discharge that results in an AC power output of the Storage Facility’s maximum discharging level and maintain the discharging state until the earlier of (a) the Facility has discharged at the maximum discharging level for four (4) consecutive hours, (b) the Storage Facility has reached 0% SOC, or (c) the sustained discharging level is at least 2% less than the maximum discharging level.
(7) Record and store the Storage Facility SOC after four (4) hours of continuous discharging. Such data point shall be used for purposes of calculation of the Battery Discharging Factor.
(8) Record and store the Discharging Energy as measured at the Storage Facility Meter. Such data point shall be used for purposes of calculation the Effective Storage Capacity.
(9) If the Storage Facility has not reached 0% SOC pursuant to Section III.A.6, continue discharging the Storage Facility until it reaches a 0% SOC. (10) Record and store the Discharging Energy (in MWh) as measured at the Storage Facility Meter, if applicable.
• Test Results
(1) The resulting Effective Storage Capacity measurement is the sum of the total Discharging Energy at the Storage Facility Meter divided by four (4) hours.

B. AGC Discharge Test
• Purpose: This test will demonstrate the AGC discharge capability to achieve the Storage Facility’s maximum discharging level within 1 second. • System starting state: The Storage Facility will be in the on-line state at 50% SOC and at an initial active power level of 0 MW and reactive power level of 0 MVAR. The EMS will be configured to follow a predefined agreed-upon active power profile. • Procedure:
(1) Record the Storage Facility active power level at the Storage Facility Meter. (2) Command the Storage Facility to follow a simulated CAISO RIG signal of 75 MW for ten (10) minutes.
(3) Record and store the Storage Facility active power response (in seconds). • System end state: The Storage Facility will be in the on-line state and at a commanded active power level of 0 MW.

Exhibit O - 7
C. AGC Charge Test
• Purpose: This test will demonstrate the AGC charge capability to achieve the Storage Facility’s full charging level within 1 second.
• System starting state: The Storage Facility will be in the on-line state at 50% SOC and at an initial active power level of 0 MW and reactive power level of 0 MVAR. The Storage Facility control system will be configured to follow a predefined agreed-upon active power profile.
• Procedure:
(1) Record the Storage Facility active power level at the Storage Facility Meter. (2) Command the Storage Facility to follow a simulated CAISO RIG signal of -100 MW for ten (10) minutes.
(3) Record and store the Storage Facility active power response (in seconds). • System end state: The Storage Facility will be in the on-line state and at a commanded active power level of 0 MW.

Exhibit P - 1

EXHIBIT P

ANNUAL STORAGE CAPACITY AVAILABILITY CALCULATION
(a) Following the end of each calendar month during the Delivery Term, Buyer shall calculate the year-to-date (YTD) “Annual Storage Capacity Availability” for the current Contract Year using the formula set forth below:

Annual Storage Capacity Availability (%) = 1 –
Unavailable Calculation Intervals
Total YTD Calculation Intervals
“Calculation Interval” or “C.I.” means each successive five-minute interval but excluding all such intervals which by the express terms of the Agreement are disregarded or excluded.
“Unavailable Calculation Intervals” means the sum of year-to-date unavailable Calculation Intervals for the applicable Contract Year, where for each Calculation Interval:
“A” is the “Available Effective Storage Capacity,” which shall be the sum of the capacity, in MW AC, expected from each system inverter in such Calculation Interval (based on normal operating conditions pursuant to the manufacturer’s guidelines), but “A” shall never exceed the Effective Storage Capacity.
“Storage Capability” means the sum of the following (taking into account the SOC at the time of calculation): (i) the energy throughput capability in MWhs in the applicable Calculation Interval that the Storage Facility is available to be charged (calculated as the available battery charging capability (in MWh) at the applicable Calculation Interval x the Battery Charging Factor) and (ii) the energy throughput capability in MWhs at the applicable Calculation Interval that the Storage Facility is available to be discharged (calculated as the available battery discharging capability (in MWh) at the applicable Calculation Interval x the Battery Discharging Factor). In calculating Storage Capability, the “available battery charging capability” and “available battery discharging capability” are calculated assuming normal operating conditions pursuant to the manufacturer’s guidelines.
(b) “Total YTD Calculation Intervals” means, for each applicable Contract Year, the total number of Calculation Intervals year-to-date up through and including the month for which the Annual Storage Capacity Availability is being calculated. The “available Effective Storage Capacity” and “Storage Capability” in the above calculations shall be the lower of (i) such amounts reported by Seller’s real-time EMS data feed to Buyer for the Storage Facility for such Calculation Unavailable
Calculation Interval = 1 C.I. x (
1 – the lesser of: Aor
Storage
Capability
(MWh)
Effe
Storage
ctive )
Capacity
Effective Storage
Capacity x 4 hrs
Exhibit P - 2
Interval, and (ii) Seller’s most recent Availability Notice (as updated pursuant to Section 4.3).

Except as otherwise expressly provided in this Agreement, the calculations of “available Effective Storage Capacity” and “Storage Capability” in the foregoing shall be based solely on the availability of the Storage Facility to charge or discharge Energy between the Storage Facility and the Generating Facility or Delivery Point, as applicable (excluding for reasons at the high-voltage side of the Delivery Point or beyond).
(c) In the first and second Contract Year, for the final year-end Storage Capacity Availability Payment True-Up Amount, the YTD Annual Storage Capacity Availability shall be increased by an amount equal to the ratio of Planned Outage hours as defined in Section 4.6 divided by 8760 hours, not to exceed . For the purposes of this calculation, if the Planned Outage is for less than a full hour, the Planned Outage will be counted as an equivalent percentage of the applicable hour. If, during any applicable hour, the Planned Outage is for less than the Effective Storage Capacity, the Planned Outage shall be counted as an equivalent percentage of such hour.

Exhibit Q - 1

EXHIBIT Q

OPERATING RESTRICTIONS
The Parties will develop and finalize the Operating Restrictions prior to the Commercial Operation Date; provided, the Operating Restrictions (i) may not be materially more restrictive of the operation of the Storage Facility than as set forth below, unless agreed to by Buyer in writing, (ii) will, at a minimum, include the rules, requirements and procedures set forth in this Exhibit Q, (iii) will include protocols and parameters for Seller’s operation of the Storage Facility in the absence of Charging Notices, Discharging Notices or other similar instructions from Buyer relating to the use of the Storage Facility, and (iv) may include Storage Facility Scheduling, Operating Restrictions and Communications Protocols.

I. STORAGE FACILITY OPERATING RESTRICTIONS
File Update Date: [XX/XX/20XX]
Technology: Lithium Ion Batteries
Storage Unit Name: [Unit Name and Number]
A. Contract Capacity
Guaranteed Storage Capacity (MW): 75
Effective Storage Capacity (MW): 75
B. Total Unit Dispatchable Range Information
Interconnect Voltage (kV) 115
Maximum Storage Level (MWh): 300
Minimum Storage Level (MWh): 0
Stored energy capability (MWh): 300
Maximum Discharge (MW): 75
Maximum Charge (MW): 75
Guaranteed Efficiency Rate: See Cover Sheet
Maximum energy throughput (BET) (MWh/year):

C. Charge and Discharge Rates
Mode Maximum
(MW)
Ramp Rate (MW/s) Description
Energy (Charge) 75 75 MW/s
Energy (Discharge) 75 75 MW/s
D. Ancillary Services
Frequency regulation is included: Yes
Spin is included: Yes
II. GENERATING FACILITY OPERATING RESTRICTIONS

1. Maximum energy throughput of MWh/year

2. Maximum annual average State of Charge (SOC) of less than Exhibit R - 1

EXHIBIT R

METERING DIAGRAM
Exhibit S - 1

EXHIBIT S

FORM OF COLLATERAL ASSIGNMENT AGREEMENT
This CONSENT AND AGREEMENT (this “Consent”), dated as of ___________, 20[ ], is executed by and among [BUYER], a [legal form of Contracting Party] organized under the laws of the State of California (the “Contracting Party”), [__________], a [___________] (the “Project Owner”), and [_____________], as collateral agent (in such capacity, together with its successors and permitted assigns, the “Collateral Agent”) for various financial institutions named from time to time as Lenders under the Credit Agreement (as defined below) and any other parties (or any of their agents) who hold any other secured indebtedness permitted to be incurred under the Credit Agreement (the Collateral Agent and all such parties collectively, the “Secured Parties”).

A. The Project Owner owns, operates and maintains [_________________] (the “Project”).

B. The Contracting Party and the Project Owner have entered into the agreement specified in Schedule I hereto (as further amended, restated, supplemented or otherwise modified from time to time in accordance with the terms thereof and hereof, the “Assigned Agreement”).

C. The Borrower, the Project Owner, the other affiliates of the Borrower as Guarantors, various financial institutions named therein from time to time as Lenders, [_________________], as the Administrative Agent and Collateral Agent, have entered into a Credit Agreement, dated as of [________________](as amended, modified or supplemented from time to time, the “Credit Agreement”), providing for the extension of the credit facilities described therein.

D. As security for the payment and performance by the Project Owner of its obligations under the Credit Agreement and the other Financing Documents (as defined below) and for other obligations owing to the Secured Parties, the Project Owner has assigned all of its right, title and interest in, to and under, and granted a security interest in, the Assigned Agreement to the Collateral Agent pursuant to the Assignment and Security Agreement, dated as of [_____________________]between the Project Owner and the Collateral Agent (as amended, restated, supplemented or otherwise modified from time to time in accordance with the terms thereof, the "Security Agreement", and, together with the Credit Agreement and any other financing documents relating to the issuance of the Notes, the “Financing Documents”).

E. It is a requirement under the Credit Agreement that the Project Owner cause the Contracting Party to execute and deliver this Consent.

NOW, THEREFORE as an inducement for Lenders to make the Loans, and for other good and valuable consideration, the receipt and adequacy of which is hereby acknowledged, and intending to be legally bound, the parties hereto hereby agree as follows:

Exhibit S - 2

1. Consent to Assignment. The Contracting Party hereby acknowledges and consents to the pledge and assignment of all right, title and interest of the Project Owner in, to and under (but not its obligations, liabilities or duties with respect to) the Assigned Agreement by the Project Owner to the Collateral Agent pursuant to the Security Agreement.

2. Representations and Warranties. The Contracting Party represents and warrants as follows:
(a) No Amendments. [Except as described in Schedule I hereto,] there are no amendments, modifications or supplements (whether by waiver, consent or otherwise) to the Assigned Agreement, either oral or written.
(b) No Previous Assignments. The Contracting Party affirms that it has no notice of any assignment relating to the right, title and interest of the Project Owner in, to and under the Assigned Agreement other than the pledge and assignment to the Collateral Agent referred to in Section 1 above.
(c) No Termination Event: No Disputes. After giving effect to the pledge and assignment referred to in Section 1, and after giving effect to the consent to such pledge and assignment by the Contracting Party, there exists no event or condition (a “Termination Event”) that would, either immediately or with the passage of time or giving of notice, or both, entitle either the Project Owner or the Contracting Party to terminate the Assigned Agreement or suspend the performance of its obligations under the Assigned Agreement. [Except as set forth on Schedule III hereto,] there are no unresolved disputes between the parties under the Assigned Agreement. All amounts due under the Assigned Agreement as of the date hereof have been paid in full [, except as set forth on Schedule III hereto].

3. Right to Cure.
(a) From and after the date hereof and unless and until the Contracting Party shall have received written notice from the Collateral Agent that the lien of the Security Agreement has been released in full, the Collateral Agent shall have the right, but not the obligation, following an “event of default” or “default” (or any other similar event however defined) by the Project Owner under the Assigned Agreement, to pay all sums due under the Assigned Agreement by the Project Owner and to perform any other act, duty or obligation required of the Project Owner thereunder as described in Section 3(c) below; provided, that no such payment or performance shall be construed as an assumption by the Collateral Agent or any other Secured Party of any covenants, agreements or obligations of the Project Owner under or in respect of the Assigned Agreement. (b) The Contracting Party agrees that it will not (i) terminate the Assigned Agreement or (ii) suspend the performance of any of its obligations under the Assigned Agreement without first giving the Collateral Agent notice and opportunity to cure as provided below. The Contracting Party further agrees that it will not assign any obligation under the Assigned Agreement without the prior consent of the Collateral Agent, which consent shall not be unreasonably withheld, delayed or conditioned, except to the extent the Contracting Party may subcontract such obligations to other parties.

Exhibit S - 3
(c) If a Termination Event shall occur, and the Contracting Party shall then be entitled to and shall desire to terminate the Assigned Agreement or suspend the performance of any of its obligations under the Assigned Agreement, the Contracting Party shall, prior to exercising such remedies or taking any other action with respect to such Termination Event, give written notice to the Collateral Agent of such Termination Event.

Collateral Agent will have the right, but not the obligation, to cure a Termination Event on behalf of Project Owner, only if Collateral Agent sends a written notice to Contracting Party before the later of (i) the expiration of any cure period under this Agreement, and (ii) fifteen (15) Business Days after Collateral Agent’s receipt of notice of such Termination Event from Contracting Party, indicating Collateral Agent’s intention to cure. If the Collateral Agent elects to exercise its right to cure as herein provided by providing a written notice to the Contracting Party, it shall have a period of (1) thirty (30) days after receipt by it of notice from the Contracting Party referred to in the preceding sentence in which to cure the Termination Event specified in such notice if such Termination Event consists of a payment default, or (2) if such Termination Event is an event other than a failure to pay amounts due and owing by the Project Owner (a “Non-monetary Event”), the Collateral Agent shall have sixty (60) days to cure such Termination Event so long as the Collateral Agent has commenced and is diligently pursuing appropriate action to cure such Termination Event; provided, however, that (i) if possession of the Project is necessary to cure such Non-monetary Event and the Collateral Agent has commenced foreclosure proceedings, the Collateral Agent will be allowed a reasonable time to complete such proceedings, and (ii) if the Collateral Agent is prohibited from curing any such Non-monetary Event by any process, stay or injunction issued by any governmental authority or pursuant to any bankruptcy or insolvency proceeding or other similar proceeding involving the Project Owner, then the time periods specified herein for curing a Termination Event shall be extended for the period of such prohibition; provided, further, that in the event of items (i) or (ii) above, such time period shall not exceed one hundred eighty (180) days. Any cure period for the Collateral Agent shall not commence until the later of (i) the end of the cure period of the Project Owner under the Assigned Agreement and (ii) written notice from the Contracting Party to the Collateral Agent of a Termination Event.
(d) Any curing of or attempt to cure any Termination Event shall not be construed as an assumption by the Collateral Agent or the other Secured Parties of any covenants, agreements or obligations of the Project Owner under or in respect of the Assigned Agreement.
(e) Following a Termination Event by the Project Entity under the Assigned Agreement, the Contracting Party may require the Collateral Agent, if the Collateral Agent has provided the notice set forth in subsection (c) above, to provide to Contracting Party a report concerning:
(i) The status of efforts by Collateral Agent to develop a plan to cure the Termination Event;
(ii) Impediments to the cure plan or its development;
Exhibit S - 4
(iii) If a cure plan has been adopted, the status of the cure plan’s implementation (including any modifications to the plan as well as the expected timeframe within which any cure is expected to be implemented); and (iv) Any other information which Contracting Party may reasonably require related to the development, implementation and timetable of the cure plan.

Collateral Agent must provide the report to Contracting Party within twenty (20) Business Days after Notice from Contracting Party requesting the report. Contracting Party will have no further right to require the report with respect to a particular Termination Event after that Termination Event has been cured.

4. Replacement Agreements. Notwithstanding any provision in the Assigned Agreement to the contrary, in the event (i) the Assigned Agreement is rejected or otherwise terminated as a result of any bankruptcy, insolvency, reorganization or similar proceedings affecting the Project Owner, at the Collateral Agent’s request within forty-five (45) days after such rejection or termination, the Contracting Party will enter into a new agreement with the Collateral Agent or the Collateral Agent’s designee for the remainder of the originally scheduled term of the Assigned Agreement, effective as of the date of such rejection, with the same covenants, agreements, terms, provisions and limitations as are contained in the Assigned Agreement, or (ii) if the Collateral Agent or its designee, directly or indirectly, takes possession of, or title to, the Project (including possession by a receiver or title by foreclosure or deed in lieu of foreclosure) after any such rejection or termination of the Assigned Agreement, promptly after the Contracting Party’s written request, the Collateral Agent must itself or must cause its designee to promptly enter into a new agreement with the Contracting Party having substantially the same terms as the Assigned Agreement for the remaining term thereof, provided that in the event a designee of the Collateral Agent, directly or indirectly, takes possession of, or title to, the Project (including possession by a receiver or title by foreclosure or deed in lieu of foreclosure), such designee shall be approved by the Contracting Party, not to be unreasonably withheld.

5. Substitute Owner. If the Collateral Agent elects to sell or transfer the Project (after the Collateral Agent directly or indirectly, takes possession of, or title to the Project), or sale of the Project occurs through the actions of the Collateral Agent (for example, a foreclosure sale where a third party is the buyer, or otherwise), then the Collateral Agent must cause the transferee or buyer to assume all of the Project Entity’s obligations arising under the Assigned Agreement and all related agreements as a condition of the sale or transfer. Such sale or transfer may be made only to an entity that (i) meets the definition of “Permitted Transferee” as defined in the Assigned Agreement and (ii) is an entity that the Contracting Party is permitted to contract with under applicable law.

6. Payments. The Contracting Party shall make all payments due to the Project Owner under the Assigned Agreement directly into the account specified on Schedule II hereto, or to such other person or account as shall be specified from time to time by the Collateral Agent to the Contracting Party in writing. All parties hereto agree that each payment by the Contracting Party as specified in the preceding sentence of amounts due to the Project Owner from the Contracting Party under the Assigned Agreement shall satisfy the Contracting Party’s corresponding payment obligation under the Assigned Agreement.

Exhibit S - 5

7. No Amendments. The Contracting Party acknowledges that the Financing Documents restrict the right of the Project Owner to amend or modify the Assigned Agreement, or to waive or provide consents with respect to certain provisions of the Assigned Agreement, unless certain conditions specified in the Financing Documents are met. The Contracting Party shall not, without the prior written consent of the Collateral Agent which consent shall not be unreasonably withheld, delayed or conditioned, amend or modify the Assigned Agreement in any material respect, or accept any waiver or consent with respect to certain provisions of the Assigned Agreement. The Collateral Agent shall have the right to consent before any termination of the Assigned Agreement which does not arise out of a Termination Event.

8. Notices. Notice to any party hereto shall be in writing and shall be deemed to be delivered on the earlier of: (a) the date of personal delivery, (b) postage prepaid, registered or certified mail, return receipt requested, or sent by express courier, in each case addressed to such party at the address indicated below (or at such other address as such party may have theretofore specified by written notice delivered in accordance herewith), upon delivery or refusal to accept delivery, or (c) if transmitted by facsimile, the date when sent and facsimile confirmation is received; provided that any facsimile communication shall be followed promptly by a hard copy original thereof by express courier:

The Collateral Agent: [________________________]
[ ]
Attn: [ ]
Telephone No.: [ ]
Facsimile No.: [ ]
The Project Owner:

The Contracting Party:

9. Successors and Assigns. This Consent shall be binding upon and shall inure to the benefit of the successors and assigns of the Contracting Party, and shall inure to the benefit of the Collateral Agent, the other Secured Parties, the Project Owner and their respective successors, transferees and assigns.

10. Counterparts. This Consent may be executed in one or more counterparts with the same effect as if the signatures thereto and hereto were upon the same instrument.

Exhibit S - 6

11. Governing Law. This Consent shall be governed by and construed in accordance with the laws of the State of [__________].
[Signature page follows on next page.]
Exhibit S - 7
IN WITNESS WHEREOF, the parties hereto have caused their duly authorized officers to execute and deliver this Consent as of the date first written above. [NAME OF CONTRACTING PARTY]
By:

Name:

Title:
[________________________]
as Collateral Agent
By:

Name:

Title:

Acknowledged and Agreed:
[_____________________________]
By:

Name:

Title:

Exhibit S - 8
Schedule I
Assigned Agreement
Exhibit S - 9
Schedule II
Payment Instructions
(Section 6)
All payments due to the Project Owner pursuant to the Assigned Agreement shall be made to [INSERT REVENUE ACCOUNT INFORMATION].

Exhibit S - 10
[Schedule III]
[Amounts Due and Unpaid under the Assigned Agreement
(Section 2(c))]
Item 19
1 VALLEY CLEAN ENERGY ALLIANCE
RESOLUTION NO. 2022-___

RESOLUTION OF THE BOARD OF DIRECTORS OF THE VALLEY CLEAN ENERGY ALLIANCE (VCE) APPROVING A POWER PURCHASE AGREEMENT (PPA) AMENDMENT 1 WITH RESURGENCE

SOLAR I, LLC AND AUTHORIZING THE EXECUTIVE OFFICER IN CONSULTATION WITH LEGAL

COUNSEL TO FINALIZE AND EXECUTE THE POWER PURCHASE AGREEMENT AMENDMENT WHEREAS, the Valley Clean Energy Alliance (“VCE”) was formed as a community choice aggregation agency (“CCA”) on November 16, 2016, under the Joint Exercise of Power Act, California Government Code sections 6500 et seq., among the County of Yolo, and the Cities of Davis and Woodland, to reduce greenhouse gas emissions, provide electricity, carry out programs to reduce energy consumption, develop local jobs in renewable energy, and promote energy security and rate stability in all of the member jurisdictions. The City of Winters, located in Yolo County, was added as a member of VCE and a party to the JPA in December of 2019; and,
WHEREAS, on January 21, 2021, VCE and Resurgence Solar 1 LLC entered into a PPA for the output from the Resurgence renewable resource for a term of 20 years; and WHEREAS, NextEra Energy Resources is developing and constructing the Resurgence project consisting of a 90-MW AC solar photovoltaic facility coupled with a 75-MW/300MWh (4-hour) lithium-ion battery energy storage system, near the city of Boron in San Bernardino County, California; and
WHEREAS, Resurgence Solar I, LLC is a wholly owned subsidiary of NextEra Energy Resources; and
WHEREAS, NextEra Energy Resources has claimed significant cost increases and associated delays due to events outside of the developer’s control; and WHEREAS, VCE and Resurgence Solar 1 LLC resolved the matters related to cost increases and associated delays as outlined in the terms of Amendment 1.

NOW, THEREFORE, the Board of Directors of the Valley Clean Energy Alliance resolves as follows:

1. The Executive Officer is authorized to execute the PPA Amendment 1 substantially in the form attached hereto as Attachment A on behalf of VCE, and, in consultation with legal counsel, is authorized to approve minor changes to the PPA Amendment so long as the term and price are not changed.

Item 19
2 PASSED, APPROVED, AND ADOPTED, at a regular meeting of the Valley Clean Energy Alliance, held on the ___ day of _____________ 2022, by the following vote:

AYES:

NOES:

ABSENT:

ABSTAIN:
_____________________________________
Jesse Loren, VCE Chair
_________________________________
Alisa M. Lembke, VCE Board Secretary
Attachment A: Amendment 1 to Resurgence Solar I LLC Power Purchase Agreement (redacted) Attachment B: Resurgence Solar I LLC Power Purchase Agreement (redacted) Item 19
3 ATTACHMENT A
AMENDMENT 1 TO RESURGENCE SOLAR I, LLC POWER PURCHASE AGREEMENT (REDACTED)
Item 19
4 ATTACHMENT B

RESURGENCE SOLAR I, LLC POWER PURCHASE AGREEMENT
(REDACTED)

Valley Clean Energy Board of DirectorsJuly 14, 2022

Valley Clean Energy Board of Directors
July 14, 2022