Diamond Bar City Council
July 15, 2025

CONSULTING SERVICES AGREEMENT
Design Professional
THIS AGREEMENT (the "Agreement") is made as of JuO\ 1, 2025 by and between the City of Diamond Bar, a municipal corporation ("City") and Dudek, a California corporation ("Consultant").

1. Consultant's Services.

Subject to the terms and conditions set forth in this Agreement Consultant shall provide to the reasonable satisfaction of the City the completion of Professional Land Surveying Services set forth in the attached Scope of Work attached hereto as Exhibit "A" in accordance with Consultant’s Proposal, dated February 6, 2025, attached hereto as Exhibit “B.” Exhibits “A” and “B” are hereby incorporated into this Agreement by reference as if set forth in full herein. As a material inducement to the City to enter into this Agreement, Consultant represents and warrants that it has thoroughly investigated the work and fully understands the difficulties and restrictions in performing the work.

Consultant represents that it is fully qualified to perform such consulting services by virtue of its experience and the training, education and expertise of its principals and employees.

Jason Williams (Maintenance Supervisor) (herein referred to as the “City’s Project Manager”), shall be the person to whom the Consultant will report for the performance of services hereunder. It is understood that Consultant shall coordinate its services hereunder with the City’s Project Manager to the extent required by the City’s Project Manager, and that all performances required hereunder by Consultant shall be performed to the satisfaction of the City’s Project Manager and the City Manager

2. Term of Agreement. This Agreement shall take effect JuO\ 1, 2025, and shall continue until June 30, 2026 (“Term”), unless earlier terminated pursuant to the provisions herein.

3. Compensation. City agrees to compensate Consultant for each service which Consultant performs to the satisfaction of City in compliance with the scope of services set forth in Exhibit "A". Payment will be made only after submission of proper invoices in the form specified by City. Total payment to Consultant pursuant to this Agreement shall not exceed twenty-nine thousand two hundred forty-five dollars and zero cents ($29,245.00) without the prior written consent of the City. The above not to exceed amount shall include all costs, including, but not limited to, all clerical, administrative, overhead, telephone, travel and all related expenses.

4. Payment.

A. As scheduled services are completed, Consultant shall submit to City an invoice for the services completed, authorized expenses and authorized extra work actually performed or incurred.
3URIHVVLRQDO/DQG6XUYH\LQJ6HUYLFHV  &RQVXOWLQJ6HUYLFHV$JUHHPHQW 














B. All such invoices shall state the basis for the amount invoiced, including services completed, the number of hours spent, and any extra work performed.

C. City will pay Consultant the amount properly invoiced within 35 days of receipt, but may withhold 30% of any invoice until all work is completed, which sum shall be paid within 35 days of completion of the work and receipt of all deliverables.

D. Payment shall constitute payment in full for all services, authorized costs and authorized extra work covered by that invoice.

5. Change Orders. No payment for extra services caused by a change in the scope or complexity of work, or for any other reason, shall be made unless and until such extra services and a price therefore have been previously authorized in writing and approved by the City Manager or his designee as an amendment to this Agreement. The amendment shall set forth the changes of work, extension of time, if any, and adjustment of the fee to be paid by City to Consultant.

6. Priority of Documents. In the event of any inconsistency between the provisions of this Agreement and any attached exhibits, the following order of precedence shall apply: (a) this Agreement; (b) the Scope of Work (Exhibit “A”); and (c) Consultant’s Proposal (Exhibit “B”).

7. Status as Independent Contractor.

A. Consultant is, and shall at all times remain as to City, a wholly independent contractor. Consultant shall have no power to incur any debt, obligation, or liability on behalf of City or otherwise act on behalf of City as an agent. Neither City nor any of its agents shall have control over the conduct of Consultant or any of Consultant's employees, except as set forth in this Agreement. Consultant shall not, at any time, or in any manner, represent that it or any of its agents or employees are in any manner agents or employees of City.

B. Consultant agrees to pay all required taxes on amounts paid to Consultant under this Agreement, and to indemnify and hold City harmless from any and all taxes, assessments, penalties, and interest asserted against City by reason of the independent contractor relationship created by this Agreement. In the event that City is audited by any Federal, State agency, including the Public Employee Retirement System, regarding the independent contractor status of Consultant and the audit in any way fails to sustain the validity of a wholly independent contractor relationship between City and Consultant, its employees or subconsultants, then Consultant agrees to reimburse City for all costs, including accounting and attorney's fees, arising out of such audit and any appeals relating thereto.

C. Consultant shall fully comply with Workers' Compensation laws regarding Consultant and Consultant's employees. Consultant further agrees to indemnify and hold City harmless from any failure of Consultant to comply with applicable Worker's Compensation laws.
3URIHVVLRQDO/DQG6XUYH\LQJ6HUYLFHV  &RQVXOWLQJ6HUYLFHV$JUHHPHQW 














D. Consultant shall, at Consultant’s sole cost and expense fully secure and comply with all federal, state and local governmental permit or licensing requirements, including but not limited to a business license with the City of Diamond Bar.

E. In addition to any other remedies it may have, City shall have the right to offset against the amount of any fees due to Consultant under this Agreement any amount due to City from Consultant as a result of Consultant's failure to promptly pay to City any reimbursement or indemnification required by this Agreement or for any amount or penalty levied against the City for Consultant’s failure to comply with this Section.

8. Standard of Performance. Consultant shall perform all work at the standard of care and skill ordinarily exercised by members of the profession under similar conditions and represents that it and any subcontractors it may engage, possess any and all licenses which are required to perform the work contemplated by this Agreement and shall maintain all appropriate licenses during the performance of the work.

9. Indemnification. To the maximum extent permitted by Civil Code section 2782.8, Consultant shall defend, indemnify and hold harmless City, its officers, officials, employees and volunteers ("Indemnitees") from and against all liability, loss, damage, expense, cost (including without limitation reasonable attorneys' fees, expert fees and all other costs and fees of litigation) of every nature arising out of or in connection with:
(1) Any and all claims under Worker’s Compensation acts and other employee benefit acts with respect to Consultant’s employees or Consultant’s contractors; (2) Any and all claims arising out of Consultant's performance of work hereunder or its failure to comply with any of its obligations contained in this Agreement. Should City in its sole discretion find Consultant’s legal counsel unacceptable, then Consultant shall reimburse the City its costs of defense, including without limitation reasonable attorneys' fees, expert fees and all other costs and fees of litigation. The Consultant shall promptly pay any final judgment rendered against the Indemnitees. Except for the Indemnitees, this Agreement shall not be construed to extend to any third-party indemnification rights of any kind; and
(3) Any and all claims for loss, injury to or death of persons or damage to property caused by the negligent professional act or omission in the performance of professional services pursuant to this Agreement.
(4) The Consultant's obligations to indemnify, defend and hold harmless the City shall survive termination of this Agreement.

Notwithstanding the foregoing, with respect to any professional liability claim or lawsuit, this indemnity does not include providing the primary defense of City, provided, however, Consultant shall be responsible for City’s defense costs to the extent such costs are incurred as a result of Consultant’s negligence, recklessness or willful misconduct.
3URIHVVLRQDO/DQG6XUYH\LQJ6HUYLFHV  &RQVXOWLQJ6HUYLFHV$JUHHPHQW 















10. Insurance.

A. Consultant shall at all times during the term of this Agreement carry, maintain, and keep in full force and effect, with an insurance company authorized to do business in the State of California and approved by the City the following insurance:
(1) a policy or policies of broad-form comprehensive general liability insurance written on an occurrence basis with minimum limits of $1,000,000.00 combined single limit coverage against any injury, death, loss or damage as a result of wrongful or negligent acts by Consultant, its officers, employees, agents, and independent contractors in performance of services under this Agreement; (2) property damage insurance with a minimum limit of $500,000.00 per occurrence;
(3) automotive liability insurance written on an occurrence basis covering all owned, non-owned and hired automobiles, with minimum combined single limits coverage of $1,000,000.00;
(4) Worker's Compensation insurance when required by law, with a minimum limit of $500,000.00 or the amount required by law, whichever is greater; and (5) Professional liability insurance covering errors and omissions arising out of the performance of this Agreement with a combined single limit of $1,000,000. If such insurance is on a claims’ made basis, Consultant agrees to keep such insurance in full force and effect for at least five years after termination or date of completion of this Agreement.

B. The City, its officers, employees, agents, and volunteers shall be named as additional insureds on the policies as to comprehensive general liability, property damage, and automotive liability. The policies as to comprehensive general liability, property damage, and automobile liability shall provide that they are primary, and that any insurance maintained by the City shall be excess insurance only.

C. All insurance policies shall provide that the insurance coverage shall not be non-renewed, canceled, reduced, or otherwise modified (except through the addition of additional insureds to the policy) by the insurance carrier without the insurance carrier giving City ten (10) day's prior written notice thereof. Consultant agrees that it will not cancel, reduce or otherwise modify the insurance coverage and in the event of any of the same by the insurer to immediately notify the City.

D. All policies of insurance shall cover the obligations of Consultant pursuant to the terms of this Agreement and except for professional liability insurance, shall be issued by an insurance company which is authorized to do business in the State of California or which is approved in writing by the City; and shall be placed have a current A.M. Best's rating of no less than A-, VII. In the case of professional liability insurance, such coverage shall be issued by companies either licensed or admitted to conduct 3URIHVVLRQDO/DQG6XUYH\LQJ6HUYLFHV  &RQVXOWLQJ6HUYLFHV$JUHHPHQW 














business in the State of California so long as such insurers possesses the aforementioned Best's rating.

E. Consultant shall submit to City (1) insurance certificates indicating compliance with the minimum insurance requirements above, and (2) insurance policy endorsements or a copy of the insurance policy evidencing the additional insured requirements in this Agreement, in a form acceptable to the City.

F. Self-Insured Retention/Deductibles. All policies required by this Agreement shall allow City, as additional insured, to satisfy the self-insured retention (“SIR”) and/or deductible of the policy in lieu of the Consultant (as the named insured) should Consultant fail to pay the SIR or deductible requirements. The amount of the SIR or deductible shall be subject to the approval of the City. Consultant understands and agrees that satisfaction of this requirement is an express condition precedent to the effectiveness of this Agreement. Failure by Consultant as primary insured to pay its SIR or deductible constitutes a material breach of this Agreement. Should City pay the SIR or deductible on Consultant’s due to such failure in order to secure defense and indemnification as an additional insured under the policy, City may include such amounts as damages in any action against Consultant for breach of this Agreement in addition to any other damages incurred by City due to the breach.

G. Subrogation. With respect to any Workers' Compensation Insurance or Employer's Liability Insurance, the insurer shall waive all rights of subrogation and contribution it may have against the Indemnitees.

H. Failure to Maintain Insurance. If Contractor fails to keep the insurance required under this Agreement in full force and effect, City may take out the necessary insurance and any premiums paid, plus 10% administrative overhead, shall be paid by Consultant, which amounts may be deducted from any payments due Consultant.

I. Consultant shall include all subcontractors, if any, as insureds under its policies or shall furnish separate certificates and endorsements for each subcontractor to the City for review and approval. All insurance for subcontractors shall be subject to all of the requirements stated herein.

11. Confidentiality. Consultant in the course of its duties may have access to confidential data of City, private individuals, or employees of the City. Consultant covenants that all data, documents, discussion, or other information developed or received by Consultant or provided for performance of this Agreement are deemed confidential and shall not be disclosed by Consultant without written authorization by City.

City shall grant such authorization if disclosure is required by law. All City data shall be returned to City upon the termination of this Agreement. Consultant's covenant under this section shall survive the termination of this Agreement. Notwithstanding the foregoing, to the extent Consultant prepares reports of a proprietary nature specifically for and in connection with certain projects, the City shall not, except with Consultant's prior written consent, use the same for other unrelated projects. 3URIHVVLRQDO/DQG6XUYH\LQJ6HUYLFHV  &RQVXOWLQJ6HUYLFHV$JUHHPHQW 















12. Ownership of Materials. Except as specifically provided in this Agreement, all materials provided by Consultant in the performance of this Agreement shall be and remain the property of City without restriction or limitation upon its use or dissemination by City. Consultant may, however, make and retain such copies of said documents and materials as Consultant may desire.

13. Maintenance and Inspection of Records. In accordance with generally accepted accounting principles, Consultant and its subcontractors shall maintain reasonably full and complete books, documents, papers, accounting records, and other information (collectively, the “records”) pertaining to the costs of and completion of services performed under this Agreement. The City and any of their authorized representatives shall have access to and the right to audit and reproduce any of Consultant's records regarding the services provided under this Agreement. Consultant shall maintain all such records for a period of at least three (3) years after termination or completion of this Agreement. Consultant agrees to make available all such records for inspection or audit at its offices during normal business hours and upon three (3) days' notice from the City, and copies thereof shall be furnished if requested.

14. Conflict of Interest.

A. Consultant covenants that it presently has no interest and shall not acquire any interest, direct or indirect, which may be affected by the services to be performed by Consultant under this Agreement, or which would conflict in any manner with the performance of its services hereunder. Consultant further covenants that, in performance of this Agreement, no person having any such interest shall be employed by it. Furthermore, Consultant shall avoid the appearance of having any interest which would conflict in any manner with the performance of its services pursuant to this Agreement.

B. Consultant covenants not to give or receive any compensation, monetary or otherwise, to or from the ultimate vendor(s) of hardware or software to City as a result of the performance of this Agreement. Consultant's covenant under this section shall survive the termination of this Agreement.

15. Termination. The City may terminate this Agreement with or without cause upon fifteen (15) days' written notice to Consultant. The effective date of termination shall be upon the date specified in the notice of termination, or, in the event no date is specified, upon the fifteenth (15th) day following mailing of the notice. In the event of such termination, City agrees to pay Consultant for services satisfactorily rendered prior to the effective date of termination. Immediately upon receiving written notice of termination, Consultant shall discontinue performing services, unless the notice provides otherwise, except those services reasonably necessary to effectuate the termination. The City shall be not liable for any claim of lost profits. Consultant may stop work and/or terminate this Agreement upon 10 days’ written notice to City in the event City is in breach of any provision of this Agreement, and City fails to cure such breach during such 10-day period. 3URIHVVLRQDO/DQG6XUYH\LQJ6HUYLFHV  &RQVXOWLQJ6HUYLFHV$JUHHPHQW 















16. Personnel/Designated Person. Consultant represents that it has, or will secure at its own expense, all personnel required to perform the services under this Agreement. All of the services required under this Agreement will be performed by Consultant or under its supervision, and all personnel engaged in the work shall be qualified to perform such services

17. Non-Discrimination and Equal Employment Opportunity.

A. Consultant shall not discriminate as to race, color, creed, religion, sex, marital status, national origin, ancestry, age, physical or mental handicap, medical condition, or sexual orientation, in the performance of its services and duties pursuant to this Agreement, and will comply with all rules and regulations of City relating thereto.

Such nondiscrimination shall include but not be limited to the following: employment, upgrading, demotion, transfers, recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship.

B. Consultant will, in all solicitations or advertisements for employees placed by or on behalf of Consultant state either that it is an equal opportunity employer or that all qualified applicants will receive consideration for employment without regard to race, color, creed, religion, sex, marital status, national origin, ancestry, age, physical or mental handicap, medical condition, or sexual orientation.

C. Consultant will cause the foregoing provisions to be inserted in all subcontracts for any work covered by this Agreement except contracts or subcontracts for standard commercial supplies or raw materials.

18. Time of Completion. Consultant agrees to commence the work provided for in this Agreement within (5) days of being notified by the City to proceed and to diligently prosecute completion of the work within the time frame agreed to by and between the Project Manager and the Consultant.

19. Time Is of the Essence. Time is of the essence in this Agreement.

Consultant shall do all things necessary and incidental to the prosecution of Consultant's work.

20. Reserved.

21. Delays and Extensions of Time. Consultant's sole remedy for delays outside its control shall be an extension of time. No matter what the cause of the delay, Consultant must document any delay and request an extension of time in writing at the time of the delay to the satisfaction of City. Any extensions granted shall be limited to the length of the delay outside Consultant’s control. If Consultant believes that delays caused by the City will cause it to incur additional costs, it must specify, in writing, why the delay has caused additional costs to be incurred and the exact amount of such cost within 10 days of the time the delay occurs. No additional costs can be paid that exceed the not to exceed amount absent a written amendment to this Agreement. In no event shall the 3URIHVVLRQDO/DQG6XUYH\LQJ6HUYLFHV  &RQVXOWLQJ6HUYLFHV$JUHHPHQW 














Consultant be entitled to any claim for lost profits due to any delay, whether caused by the City or due to some other cause.

22. Assignment. Consultant shall not assign or transfer any interest in this Agreement nor the performance of any of Consultant's obligations hereunder, without the prior written consent of City, and any attempt by Consultant to so assign this Agreement or any rights, duties, or obligations arising hereunder shall be void and of no effect.

23. Compliance with Laws. Consultant shall comply with all applicable laws, ordinances, codes and regulations of the federal, state, and local governments.

24. Non-Waiver of Terms, Rights and Remedies. Waiver by either party of any one or more of the conditions of performance under this Agreement shall not be a waiver of any other condition of performance under this Agreement. In no event shall the making by City of any payment to Consultant constitute or be construed as a waiver by City of any breach of covenant, or any default which may then exist on the part of Consultant, and the making of any such payment by City shall in no way impair or prejudice any right or remedy available to City with regard to such breach or default.

25. Attorney's Fees. In the event that either party to this Agreement shall commence any legal or equitable action or proceeding to enforce or interpret the provisions of this Agreement, the prevailing party in such action or proceeding shall be entitled to recover its costs of suit, including reasonable attorney's fees and costs, including costs of expert witnesses and consultants.

26. Mediation. Any dispute or controversy arising under this Agreement, or in connection with any of the terms and conditions hereof, which cannot be resolved by the parties, may be referred by the parties hereto for mediation. A third party, neutral mediation service shall be selected, as agreed upon by the parties and the costs and expenses thereof shall be borne equally by the parties hereto. The parties agree to utilize their good faith efforts to resolve any such dispute or controversy so submitted to mediation. It is specifically understood and agreed by the parties hereto that mutual good faith efforts to resolve the same any dispute or controversy as provided herein, shall be a condition precedent to the institution of any action or proceeding, whether at law or in equity with respect to any such dispute or controversy.

26. Notices. Any notices, bills, invoices, or reports required by this Agreement shall be deemed received on (a) the day of delivery if delivered by hand during regular business hours or by facsimile before or during regular business hours; or (b) on the third business day following deposit in the United States mail, postage prepaid, to the addresses heretofore set forth in the Agreement, or to such other addresses as the parties may, from time to time, designate in writing pursuant to the provisions of this section. 3URIHVVLRQDO/DQG6XUYH\LQJ6HUYLFHV  &RQVXOWLQJ6HUYLFHV$JUHHPHQW 














“CONSULTANT” “CITY”
Dudek City of Diamond Bar
225 South Lake Avenue, Suite M210 21810 Copley Drive
Pasadena, CA 91101 Diamond Bar, CA 91765-4178
Attn.: Steven Hochart Attn.: Jason Williams
Phone: 808-202-0022 Phone: 909-839-7059
E-Mail: [email protected] E-mail: [email protected]

28. Governing Law. This Agreement shall be interpreted, construed and enforced in accordance with the laws of the State of California.

29. Counterparts. This Agreement may be executed in any number of counterparts, each of which shall be deemed to be the original, and all of which together shall constitute one and the same instrument.

30. Entire Agreement. This Agreement, and any other documents incorporated herein by reference, represent the entire and integrated agreement between Consultant and City. This Agreement supersedes all prior oral or written negotiations, representations or agreements. This Agreement may not be amended, nor any provision or breach hereof waived, except in a writing signed by the parties which expressly refers to this Agreement. Amendments on behalf of the City will only be valid if signed by a person duly authorized to do so under the City's Purchasing Ordinance. 3URIHVVLRQDO/DQG6XUYH\LQJ6HUYLFHV
&RQVXOWLQJ6HUYLFHV$JUHHPHQW















IN WITNESS of this Agreement, the parties have executed this Agreement as of the date first written above.
"Consultant" "City"

DUDEK CITY OF DIAMOND BAR
By: By:

Printed Name: Joseph Monaco Daniel Fox, City Manager
Title: President/CEO
By: ATTEST:

Printed Name:

Title:

Kristina Santana, City Clerk
Approved as to form:

By:

Omar Sandoval, City Attorney
*NOTE: If Consultant is a corporation, the City requires the following signature(s):
-- (1) the Chairman of the Board, the President or a Vice-President, AND (2) the Secretary, the Chief Financial Officer, the Treasurer, an Assistant Secretary or an Assistant Treasurer.

If only one corporate officer exists or one corporate officer holds more than one corporate office, please so indicate. OR
-- The corporate officer named in a corporate resolution as authorized to enter into this Agreement. A copy of the corporate resolution, certified by the Secretary close in time to the execution of the Agreement, must be provided to the City. 3URIHVVLRQDO/DQG6XUYH\LQJ6HUYLFHV  &RQVXOWLQJ6HUYLFHV$JUHHPHQW 














EXHIBIT “A”
3URIHVVLRQDO/DQG6XUYH\LQJ6HUYLFHV  &RQVXOWLQJ6HUYLFHV$JUHHPHQW([KLELW$ 















SCOPE OF WORK
The successful Consultant, at a minimum, must provide all instruments, equipment, tools, personnel, and supervision required to provide the land surveying services below.

PART I – BOUNDARY/PROPERTY LINE SURVEY
The Consultant shall conduct a detailed boundary survey, using precise measuring techniques, to identify and establish the property lines of the PONY Property located at 22601 Sunset Crossing Road, Diamond Bar, CA 91765, APN 8718-005-005 & -006 and the Sunset Crossing Property located at 22555 Sunset Crossing Road, Diamond Bar, CA 91765, APN 8718-005-900 and 8718-005-901. The Consultant shall exercise independent, professional judgment and innovation in performance of any services or tasks listed herein. At a minimum, the Consultant shall:
x Review available property records and other relevant documents. x Identify, verify, and locate any existing boundary markers, natural features, and other relevant site conditions.
x Verify that boundaries align with existing legal descriptions and recorded documents.
x Produce a detailed boundary line survey map that clearly illustrates the property boundaries and area calculations.
x Mark property corners with permanent markers. Permanent markers must be installed every 100 ft. along the eastside property line of the PONY Property adjacent to the homes on Big Falls Drive.
x Provide digital copies of all survey documentation, including the boundary line map in a PDF and Geographic Information System (“GIS”) shapefile/layer format.

PART II – UTILITY SURVEY
The Consultant must conduct a detailed utility survey to identify the types and locations of all above-ground and underground utilities within the PONY Property and the Sunset Crossing Property. The Consultant shall exercise independent, professional judgment and innovation in performance of any services or tasks listed herein. At a minimum, the Consultant shall:
x Review available public records and utility maps from local utility companies and as-built drawings to gather historical data about existing utility installations.
x Conduct a visual inspection to document all above-ground utilities, including poles, conduits, meters, and other visible installations. x Record the location, condition, and type of each utility identified during the survey.
3URIHVVLRQDO/DQG6XUYH\LQJ6HUYLFHV  &RQVXOWLQJ6HUYLFHV$JUHHPHQW([KLELW$ 














x Utilize utility locating technologies such as electromagnetic locators, groundpenetrating radars, and other non-invasive methods to identify subsurface utilities.
x Accurately locate and map existing underground utilities, including water, sewer, gas, electricity, and telecommunications.
x Produce a detailed utility survey map that includes above-ground and underground utilities, including valve locations, and distinguishes between different utility types, locations, depths, and conditions. Utility survey map must also include utilities within the sidewalk adjacent to the properties. x Provide digital copies of all survey documentation, including the utility map in a PDF and GIS shapefile/layer format.

PART III – SPECIFIC REQUIREMENTS
All work must be performed under the direction of a Registered Land Surveyor in the State of California. The surveyor must maintain professional licenses required by the laws of the State of California at all times while under contract with the City. 3URIHVVLRQDO/DQG6XUYH\LQJ6HUYLFHV  &RQVXOWLQJ6HUYLFHV$JUHHPHQW([KLELW$ 














EXHIBIT “B”
3URIHVVLRQDO/DQG6XUYH\LQJ6HUYLFHV  &RQVXOWLQJ6HUYLFHV$JUHHPHQW([KLELW% 















PROPOSAL

PROFESSIONAL LAND

SURVEYING SERVICES

CITY OF DIAMOND BAR
FEBRUARY 6, 2025
225 South Lake Avenue, Suite M210 / Pasadena, CA 91101 / 626.204.9800 














Proposal for Professional Land Surveying Services i
A. Cover Letter
February 6, 2025
City of Diamond Bar
City Manager’s Office
Attn: Alex Batres
1810 Copley Drive
Diamond Bar, California 91765
Subject: Professional Land Surveying Services
Dear Alex Batres:

Dudek is well qualified to conduct boundary and utility surveys for the City of Diamond Bar (City). We are well equipped to offer the following services:
ƒ American Land Title Association (ALTA)/
National Society of Professional Surveyors
(NSPS) Surveys
ƒ Civil Design Topographic Surveys
ƒ Aerial Lidar
ƒ Orthoimagery
ƒ Planimetrics
ƒ Utility Research
ƒ Boundary Surveys
ƒ As-Built Surveys
ƒ Lot Line Adjustments
ƒ Legal Descriptions
ƒ Records of Survey
ƒ Corner Records
ƒ Underground Utility Locating

Firm Background
Dudek was founded in 1980 in Encinitas, California, as a small civil engineering consulting practice working for municipal wastewater agencies and private land developers in San Diego County. The firm steadily grew its civil engineering practice through the 1980s, expanding throughout Southern California.

In 1990, the firm started an environmental practice in response to expanding state and federal environmental regulations. Primarily through organic growth and limited acquisitions of small firms, Dudek has grown to an 800- plus person, multidisciplinary environmental and engineering firm with offices throughout the United States.

Dudek is ranked as one of the Top 125 U.S. Environmental Firms (Engineering News-Record, 2024). Joseph Monaco serves as president and CEO.















Professional Land Surveying Services ii
Dudek Advantages
Licensed, Qualified Staff. The project team will be led by Principal-inCharge Steven Hochart, who brings decades of experience providing customized survey solutions for small- to medium-sized municipalities.

The team assembled for this contract includes highly skilled professionals, such as California licensed surveyors and civil engineers, computer-aided design technicians, geographic information system (GIS) analysts, survey field technicians, and uncrewed aerial vehicle (UAV) operators. Each team member has extensive experience in their respective disciplines, ensuring the highest level of expertise and service for City projects.

Similar Projects for Public- and Private-Sector Clients. Dudek successfully delivers survey services, including ALTA/NSPS, boundary, civil design topographic, utility locating, and Americans with Disabilities Act surveys for municipalities and state, federal, and private developers. We have vast experience in delivering quality products on schedule for municipalities with a similar size as the City. Our survey team will respond quickly to requests and task orders to meet deadlines. Our client-centered approach will provide the City with daily updates and recommendations as the project progresses. Dudek’s vast experience with on-call municipal contracts equips us with a deep understanding of the necessity for precise, design-ready deliverables.

Proven, Accurate Technology Solutions. We pride ourselves on developing innovative solutions to each project to create the most cost-effective and accurate product. We were an early adopter of UAV technology and have been delivering UAV projects for a diverse set of public- and private-sector clients since 2014. The range of UAV services delivered from our qualified team includes lidar, photogrammetry, multispectral imagery, thermal imagery, highresolution video, magnetometry, bathymetric lidar, and the full range of UAV platforms. Dudek has earned a silver designation with Esri’s partner network, providing a range of ArcGIS solutions for public- and private-sector clients.

Dudek pioneered a hybrid approach for large mapping efforts utilizing the speed of airborne remote-sensing technologies in conjunction with the accuracy provided with traditional survey services. Dudek’s GIS team provides highly accurate linework and planimetric solutions to large urban environments from aerial data, which results in a significant reduction in fieldwork.

We look forward to the opportunity to work with the City on this contract. This proposal is valid for 180 days from the date of submission. If there are any questions or follow-up needed about our qualifications, please contact Mapping and Surveying Practice Director and Principal-in-Charge Steven Hochart at 808.202.0022 or [email protected].

Sincerely,
__________________________________ __________________________________ Joseph Monaco Steven Hochart
President/CEO Principal-in-Charge
Joseph Monaco is authorized to sign on behalf of Dudek. He is authorized to bind Dudek.

DUDEK AT A GLANCE
ƒ Multidisciplinary
environmental and
engineering services
ƒ 21 offices
ƒ 800+ employees
ƒ 100% employee-owned
ƒ Top 125 U.S. Environmental
Firms (Engineering NewsRecord, 2024)















Proposal for Professional Land Surveying Services iii
Table of Contents

SECTIONS
A. Cover Letter....................................................................................................................................................................... i B. Project Team ....................................................................................................................................................................1 C. Firm’s Experience/References.......................................................................................................................................5 D. Methodology/Project Understanding.......................................................................................................................... 17 E. Cost for Services ........................................................................................................................................................... 24 F. Insurance....................................................................................................................................................................... 26 G. Consulting Services Agreement .................................................................................................................................2 TABLE
1 Key Staff Qualifications...................................................................................................................................................3

FIGURES
1 Dudek Team Organization ..............................................................................................................................................2 2 Project Delivery Process............................................................................................................................................... 21

APPENDIX
A Resumes















Proposal for Professional Land Surveying Services 1
B. Project Team
The proposed Dudek team exceeds the qualifications needed to conduct services under each category of this contract. In addition, we hold the necessary licenses to perform the work. We have assembled a team that can mobilize quickly for new projects, saving the City time and money with reduced travel costs.

The team specifically chosen for this project will consist of highly qualified personnel. Each member of the team brings the specialized skills and experience necessary to ensure the successful completion of the project. Given the team members’ current workloads, we anticipate that they will be able to efficiently manage their responsibilities for this project, providing the necessary commitment and expertise to achieve the project’s goals within the stipulated time frame with the capacity to dedicate 100% of their time to City projects. Additionally, our firm is equipped with the flexibility to increase the number of employees dedicated to this project based on the City’s needs. This scalability ensures that we can adapt to any changes in project scope or deadlines, providing additional resources as required to meet the City’s expectations and maintain project momentum.

Dudek has partnered with Ground Penetrating Radar Systems Inc. to strengthen the project team and provide underground utility locating expertise.

Dudek will notify the City if there are any changes in personnel during the contract period and will furnish the same required information for review and approval.















Professional Land Surveying Services 2
Figure 1 outlines proposed lines of communication for this contract and is followed by qualifications for primary personnel in Table 1. Key staff in the organization chart are indicated with an asterisk (*). Full resumes for key staff can be found in Appendix A.

Figure 1. Dudek Team Organization
Principal-in-Charge
Steven Hochart*
Project Manager
Ryan Shupert*

PROJECT TEAM
Professional Land
Surveyor
Armando Magana, PLS, PE

Stephen Paul, PLS* Hunter
Stetson, PLS*
CADD Drafter
Greg Mata
Mark Hudi
Underground Utility
Locate
Ground Penetrating Radar
Systems Inc.

Lead GIS Analyst
Matthew Rice
Field Surveyor
James Bocina
GIS Analyst
Craig Schifferns
Field Surveyor/UAV
Operator
Cameron Rodriguez















Professional Land Surveying Services 3
Table 1. Key Staff Qualifications
Name, Role, Education, Certifications Relevant Experience Name: Steven Hochart
Title: Principal in Charge
Education: University of California, Santa
Barbara, BA, Geography (Environmental Studies
emphasis)
ƒ City of La Cañada Flintridge On-Call Surveying, La Cañada Flintridge, California
ƒ South Coast Water District On-Call Surveying, Laguna Beach, California
ƒ Ben Clark Training Center American Land Title Association (ALTA)/National Society of Professional Surveyors (NSPS) Survey, Riverside, California
ƒ As-Built Transmission Line Survey, K-Line Hardening, Imperial Irrigation District, Coachella Valley, California
Name: Hunter Stetson
Title: Survey Manager
Education: California State University, Fresno, BA
Geomatic Engineering
Certifications: California Professional Land
Surveyor No. 9737
Role: Surveyor of Record
ƒ As-Built Transmission Line Survey, 92-kV H-Line, Imperial Irrigation District, Indio, California
ƒ As-Built Transmission Line Survey, K-Line Hardening, Imperial Irrigation District, Coachella Valley, California
ƒ Cobb Mountain CHP Tower Topographic and Boundary
Survey, Cobb Mountain, California
ƒ Hinman Dam Topographic and Hydrographic Survey,
Yountville, California
Name: Armando Magana
Title: Surveying Task Lead
Education: California Polytechnic State University,
San Luis Obispo, BS, Civil Engineering
Certifications: Professional Civil Engineer,
California No. 59563; Licensed Land Surveyor,
California LS 8232
Role: Boundary Review
ƒ City of La Cañada Flintridge On-Call Surveying, La Cañada Flintridge, California
ƒ South Coast Water District On-Call Surveying, Laguna Beach, California
ƒ Ben Clark Training Center ALTA/NSPS Survey, Riverside, California
ƒ Las Hermanas ALTA/NSPS and Topographic Survey,
Compton, California
Name: Ryan Shupert
Title: Project Manager
Education: Liberty University BS, Aeronautics
(Uncrewed Aerial Systems emphasis)
Certifications: Federal Aviation Administration
Remote Pilot Certification, Part 107, Small
Unmanned Aircraft, 2016, No. 3940189;
Private Pilot, Airplane Instrument Rating,
No. 3858922; North Carolina Department of
Transportation UAS Commercial Operator
Permit, 2023, No. C0018405; Transport
Canada Small Remotely Piloted Aircraft System,
Visual Line of Site, Basic Operators, 2024, No.

PC2305318756
Role: Client Representative, Budget Tracking
ƒ City of La Cañada Flintridge On-Call Surveying, La Cañada Flintridge, California
ƒ South Coast Water District On-Call Surveying, Laguna
Beach, California
ƒ As-Built Transmission Line Survey, 92-kV H-Line, Imperial Irrigation District, Indio, California
ƒ Ben Clark Training Center ALTA/NSPS Survey, Riverside, California
ƒ As-Built Transmission Line Survey, K-Line Hardening,
Imperial Irrigation District, Coachella Valley, California Name: Stephen Paul
Title: Professional Land Surveyor
ƒ Board of Water Supply Utility Mapping, Honolulu Board of Water Supply, Honolulu, Hawai‘i
ƒ Hawaiian Telecom Civil Design Topographic Surveys, R.M.

Towill, Oahu, Hawai‘i















Professional Land Surveying Services 4
Table 1. Key Staff Qualifications
Name, Role, Education, Certifications Relevant Experience Education: North Carolina Society of Surveyors
Institute at North Carolina State University;
Certificate of Graduation, Specialized Surveying
Curriculum
Certifications: Professional Land Surveyor (PLS),
HA No. LS-12526
Registered Land Court Surveyor, HA No. 370
PLS, Guam No. 079
PLS, NC No. L3340
Role: Survey Data QA/QC
ƒ As-Built Transmission Line Survey, 92-kV H-Line, Imperial Irrigation District, Indio, California
ƒ Ben Clark Training Center ALTA/NSPS Survey, Riverside, California















Proposal for Professional Land Surveying Services 5
C. Firm’s Experience/References
Dudek brings decades of experience delivering reliable and precise surveying services to support a wide range of public agency needs. Our team specializes in construction verification, construction staking, land surveying, and topographic surveys, ensuring accurate data collection and compliance with project specifications. We excel in establishing control points, preparing legal descriptions and plats for easements, and resolving boundary issues, all while providing high-quality deliverables tailored to client requirements. The Dudek team understands the complexities of land surveying in California. All land survey work will be conducted by a licensed California Land Surveyor and will be in conformance with the California Professional Land Surveyor’s Act. Our team is well versed in a variety of survey services to provide the City with solutions that are cost-effective and delivered on time. We specialize in the utilization of uncrewed aerial vehicle (UAV) technology when appropriate to streamline project deliverables and create a cost-competitive solution for our clients. Our experience includes completing survey tasks for water districts, state and local jurisdictions, utility providers, and private developer Our services also include preparing record drawings, plot plans, and documents for lot line adjustments or consolidations, all in adherence to applicable agency standards. By leveraging advanced technology and proven methodologies, Dudek ensures efficient and effective execution of on-call tasks, such as verifying facilities, determining right-of-way (ROW) limits, and preparing topographic maps. With a focus on quality, accuracy, and client collaboration, Dudek is well equipped to provide the dependable sur veying support the City of Diamond Bar requires.

Land Surveying
Dudek’s surveying team is composed of highly experienced professionals, including licensed California land surveyors, computer-aided design (CAD) drafters, survey crew chiefs, UAV operators, and geographic information system (GIS) analysts.

This diverse expertise ensures that every project benefits from a combination of technical skill, industry knowledge, and precision. Our personnel are dedicated to delivering accurate and timely results, leveraging their extensive experience to meet the unique requirements of each project.

We employ a blend of traditional survey methods and advanced technologies to provide comprehensive surveying solutions. Our capabilities include terrestrial scanning, UAV lidar, photogrammetry, and planimetrics, allowing us to collect and analyze data with exceptional accuracy and efficiency. These tools, combined with our commitment to quality and innovation, enable Dudek to deliver reliable and cost-effective surveying services tailored to the needs of the City. 














Professional Land Surveying Services 6
>dͬE^W^^hZs
z^
Dudek has extensive experience conducting ALTA/NSPS surveys throughout California, providing essential information for property transactions, due diligence, and development planning.

Our team of licensed surveyors ensures that every ALTA/NSPS survey adheres to the strict national standards required for real estate transfers, financing, and title insurance. These surveys include comprehensive documentation of property boundaries, easements, encroachments, and improvements, offering clarity and security for all parties involved in a real estate transaction.

We understand that each property and project presents its own set of challenges, from complex legal descriptions to sitespecific conditions. Our team works closely with property owners, title companies, and legal professionals to ensure that all aspects of the survey meet the client’s needs and comply with local and state regulations. Dudek expertise spans both urban and rural environments, and we utilize state-of-the-art equipment and technology, including GPS, total stations, and UAVs, to gather accurate and precise data. dKWK'ZW,/^hZs
z^
Dudek evaluates the needs of each project to determine the most effective and efficient ways to achieve desired results. Dudek will work with the City to identify the unique needs and requirements for each project and will select the most appropriate tools and technologies, depending on the specific requirements and limitations of each task. The licensed professional surveyors within our team have decades of experience using GPS, conventional and terrestrial
equipment, and newer technologies, such as UAV lidar, to acquire topographic data. We are highly experienced in all types of topographic surveying, including the following:
ƒ Civil design surveys for construction and
design purposes
ƒ Aerial lidar surveys
ƒ Cross-section and profiling for rivers, streams,
and canals
ƒ Hybrid topographic surveys (aerial lidar or
photogrammetric mapping used in conjunction with
ground-based techniques)
KhEZz^hZs
z^
The key to providing and performing land boundary surveys is to perform the proper research, fieldwork, proper judgment, and analysis of the information. The Dudek team performs boundary surveys on a variety of projects across California and North America. The boundary surveys show the locations of property boundaries, as well as gaps and overlaps between properties. The surveys also display the proximity of improvements to property lines Civil Design Topographic Survey
ALTA/NSPS Survey















Professional Land Surveying Services 7
and encroachments across property lines. During the boundary surveys, our licensed land surveyors will stake the property corners and/or property lines in the field as needed. Accurately completing boundary surveys requires a clear understanding of the California property cadastral system. KE^dZhd/KE^d</E'
Dudek can generate accurate as-built drawings of facilities. All surveys are integrated with local controls and site monuments to tie the surveys to existing engineering design drawings. In addition to as-built verification, Dudek performs construction staking activities to include the preparation of survey notes, cut/fill notes, staking for rough grade, finish grade, final staking position notes, as-built surveys, and other services as may be necessary to meet the City’s or its contractors’ construction schedule. Construction staking may also include horizontal control, vertical control, clearing, grading, utility, structure, ROW, monitoring, and as-builts.

While completing work, we ensure that a field crew will be on site setting stakes within 48 hours’ receipt of a staking request. Initial calculations will be performed in the office to address potential questions and/or plan discrepancies that arise, thus eliminating downtime in the field. The field packages provided to our crews allow them the flexibility to adjust reference stakes in the field and on the fly to accommodate existing field conditions and avoid delays. All points staked will be recorded for both the horizontal and vertical position, and will be available for submittal upon request.

Our team will coordinate directly with the resident engineer and the contractor to ensure that all services are completed to the accuracy standards needed for the work and will help resolve any construction staking issues.

We are comfortable working with contractors that employ Automated Machine Guidance technology, and we are ready to assist the City and its contractors in the effective use of 3D digital terrain models for efficient project delivery.
KZE
ZZ
KZ^
The Dudek team of licensed land surveyors is proficient in preparing and filing Corner Records in compliance with the California Land Surveyors Act and local county ordinances. Corner Records are essential for documenting the reestablishment or verification of property corner monuments, which are used to define the boundaries of land parcels. These records play a critical role in preserving the integrity of boundary monuments, particularly when they have been disturbed, relocated, or replaced.

Our surveyors follow a rigorous process to ensure that all Corner Records are precise, complete, and legally sound.

This includes conducting field surveys to locate, verify, or reestablish boundary monuments using a combination of traditional surveying methods and advanced technology, such as GPS and total stations. Once the fieldwork is complete, we prepare the necessary documentation, ensuring that each Corner Record includes all required information, such as monument descriptions, bearings, distances, and references to relevant Records of Survey or deeds.

Dudek has extensive experience filing Corner Records for a wide range of projects throughout California, including urban redevelopment, infrastructure projects, and land subdivisions. By adhering to state and local regulations, we ensure that each Corner Record is properly documented and submitted to the appropriate county agencies.

Our thorough approach helps protect property boundaries and provides an official, publicly accessible record that benefits both property owners and future land surveys.















Professional Land Surveying Services 8
Whether reestablishing a lost monument or verifying an existing one, Dudek’s expertise in Corner Records ensures that land boundaries are accurately preserved and legally recognized.

Z
KZ^K&^hZs
z
The Dudek team of licensed professional land surveyors has decades of experience preparing and filing Records of Survey in accordance with California’s stringent legal and regulatory requirements. A Record of Survey provides a detailed depiction of property boundaries, easements, and monumentation, offering a clear representation of land ownership and property limits. These surveys are critical for resolving boundary disputes, confirming property lines, and documenting significant changes to land parcels.

Our team works meticulously to ensure that each Record of Survey meets the highest standards of accuracy and completeness. We utilize advanced surveying techniques, including GPS, total stations, and conventional groundbased methods, to collect precise data in the field. This data is then carefully analyzed and drafted into detailed survey maps that conform to the California Land Surveyors Act and local county requirements. Whether clarifying property boundaries or recording land subdivision, Dudek’s Records of Survey provide an official and reliable document for property owners, developers, and public agencies.

Dudek has prepared and filed countless Records of Survey across a variety of complex urban, suburban, and rural landscapes in California. Our team’s extensive knowledge of local land use regulations and our attention to detail ensure that every Record of Survey is prepared efficiently and accurately, safeguarding the interests of property owners and municipalities alike. From initial fieldwork to final filing, Dudek delivers comprehensive Records of Survey that provide a solid foundation for land ownership and development.

W>d^E>
'>
^Z/Wd/KE^&KZZKtE
^
D
EdYh/^/d/KE^
Dudek excels in providing comprehensive ROW and easement acquisition support, ensuring that infrastructure and development projects proceed efficiently and without legal complications. Our experienced team specializes in preparing precise plats and legal descriptions, delivering legally sound documentation that meets the stringent requirements of local jurisdictions, utility agencies, and private landowners.

Utilizing advanced CAD and GIS technologies, we ensure the highest level of accuracy in plat development, seamlessly integrating field survey data with existing property records. Our legal descriptions are meticulously drafted to clearly define property boundaries, easement rights, and encumbrances, ensuring compliance with regulatory and title standards.

Dudek is adept at managing complex ROW scenarios involving multiple parcels, irregular boundaries, overlapping easements, and historical property records. Our expertise extends to coordinating with landowners, title companies, and legal teams to facilitate smooth transactions, minimize acquisition delays, and prevent future disputes. Whether supporting roadway expansions, utility corridors, or public infrastructure projects, our thorough approach ensures that all required documentation is complete, accurate, and defensible.

By partnering with Dudek for ROW and easement services, agencies and developers gain a trusted advisor with the technical expertise and regulatory knowledge to navigate the intricacies of property acquisition. Our commitment to precision and compliance helps streamline project approvals and supports the timely progression of critical infrastructure improvements















Professional Land Surveying Services 9

^
D
Ed^hWWKZd
As part of the property boundary surveys, Dudek regularly completes an associated ALTA survey for the identified project parcels. The ALTA surveys include legal description and exhibit preparation in support of land acquisitions, leasing, and divesting. Additionally, the Dudek team is well versed in the preparation of plat maps and legal descriptions in support of ROW acquisition and for both temporary and permanent easements in support of infrastructure development projects using metes and bounds, lot and block, and prescriptive methodologies. The Dudek team has been supporting several energy clients across North America and in California with transactional survey services.
^Ͳh/>d^hZs
z^
As-built surveys provide an accurate record of completed construction, documenting any deviations from the original design plans. They are critical for verifying project compliance, supporting closeout documentation, and facilitating future maintenance or modifications. By integrating precise data collection and thorough analysis, asbuilt surveys ensure project accountability and long-term reliability. Our as-built survey services span a broad spectrum of applications, including energy developments, battery energy storage system projects, habitat restoration, roadway installation, water systems, utilities, hiking trails, volumetric assessments, and other improvements. Data is meticulously gathered and processed to meet project-specific requirements.

Dudek is distinguished by its depth of expertise in advanced as-built data acquisition techniques and analysis.

With a keen focus on accuracy and detailed reporting, we thoroughly review historical records, verify site conditions, and document every detail to uphold the highest standards of project quality and performance.

Dudek’s thorough as-built process enables project engineers to confidently certify that the construction aligns with the approved design plans, streamlining closeout and construction.

Aerial Mapping
/ZKZE
>/Z
Our firm brings industry-leading expertise and advanced technology to land surveying and mapping services, specializing in UAV lidar operations with high-end Riegl lidar scanners. These advanced systems, renowned for their precision and reliability, enable us to capture millions of data points per second, providing exceptional accuracy and efficiency. Our UAV lidar capabilities are tailored for projects that range from a few acres to expansive areas up to 10,000 acres, making us a trusted partner for a wide variety of surveying needs.

To maximize the value of UAV lidar, we employ a hybrid survey approach that integrates the speed and broad coverage of airborne lidar with the precision of ground-based surveying techniques. Airborne lidar is used to rapidly capture large-scale topographic data and generate 1-foot contours, while ground-based surveying collects supplemental data to refine critical survey details and ensure compliance with accuracy standards and regulatory requirements. This methodology allows us to deliver results that combine efficiency with uncompromising detail. 














Professional Land Surveying Services 10
Our UAV lidar services support a broad range of applications, including topographic mapping, boundary and ALTA surveys, construction and engineering support, and environmental studies, such as floodplain modeling, wetland delineations, and forestry analysis. Deliverables are tailored to meet specific project needs and can include 1-foot contours, digital elevation models, orthophotos, 3D point clouds, CAD-ready files, and site-specific analytics, such as volume calculations.

By utilizing UAV lidar, we provide faster turnaround times, reduced costs, and unparalleled data accuracy, even in challenging or remote terrain. With extensive experience and a commitment to quality, we handle projects of all sizes and complexities, from small-scale developments to expansive multithousand-acre sites.

W,KdK'ZDD
dZzEW>E/D
dZ/^
Our photogrammetric mapping services leverage advanced aerial imaging technology to provide highly detailed and accurate geospatial data for a variety of applications. By capturing high-resolution images using state-of-the-art UAV systems, we create precise orthophotos, 3D point clouds, and digital surface models.

This method is particularly effective for projects requiring large-scale coverage and high-resolution visuals, such as site planning, infrastructure development, and environmental monitoring.

Using photogrammetry, we generate
reliable deliverables that meet stringent
accuracy requirements, including contours,
digital terrain models, and CAD-ready files
for engineering and design workflows. This
cost-effective and efficient mapping
technique allows us to produce detailed
visualizations and measurements, enabling
informed decision-making for a range of
industries. Whether your project spans a
few acres or thousands, our
photogrammetric mapping ensures fast,
reliable, and visually rich geospatial data
tailored to your needs.

Our planimetric mapping services provide
detailed 2D representations of natural and
man-made features on the earth’s surface.

Utilizing UAV technology and advanced mapping software, we extract precise data to delineate features such as buildings, roads, curbs, utilities, vegetation, and other site-specific elements. This meticulous approach ensures the accuracy and usability of planimetric data for engineering, construction, and urban planning projects.

We specialize in creating CAD-ready deliverables that integrate seamlessly into design workflows, supporting applications such as site development, infrastructure planning, and asset management. Our team combines aerial mapping techniques with ground verification as needed to produce planimetric maps with unparalleled detail and reliability. Whether for large-scale municipal projects or detailed site plans, our planimetric mapping services provide the clarity and precision necessary for effective project execution.

Recently completed planimetrics of a college campus















Professional Land Surveying Services 11
Project Experience

BEN CLARK TRAINING CENTER ALTA/NSPS AND TOPOGRAPHIC SURVEY Organization Riverside County, California Sheriff’s Department Name: Etienne Brodeur
Title: Project Engineer
Address: 4095 Lemon Street, Riverside, California 92501 Phone: 951.955.0775
Email: [email protected]
Date of Completion: 2022
Relevance to this Contract: Vertical and Horizontal Control, Boundary Surveys, Topographic Surveys, Record Drawings, Records Research and Analysis
Dudek was chosen to complete an ALTA/NSPS and topographic survey of the Ben Clark Training Center in Riverside County. The survey work was conducted to support the Department’s construction of a new state-of-theart training and educational campus for public safety, government, and educational partners to train public safety personnel with effective law enforcement and emergency response tools.

In addition to the ALTA/NSPS survey, Dudek performed several supplementary tasks, including benchmark installation, ground-based topographic surveys to support design work, and ortho-imagery acquisition of the ALTA/NSPS and Topographic Survey of the Ben Clark Training Center 














Professional Land Surveying Services 12
surrounding area. Utilizing aerial lidar technology, Dudek derived 1-foot contours across the project site and conducted aerial target surveys for precise lidar registration. Deliverables included a Civil 3D surface, stamped PDF ALTA/NSPS survey, and .dwg of the project site.

JUNE LAKE PUBLIC UTILITY DISTRICT ASSET MAPPING
Organization: June Lake Public Utility District
Name: Timothy Morris II
Title: Superintendent
Address:2380 Highway 158, June Lake, California 93529
Phone: 815.214.4166
Email: [email protected]
Period of Performance/Date of Completion: December 2024–Ongoing Relevance to this Contract: Vertical and Horizontal Control, Topographic Surveys, Utility Survey, Construction Verification, Utility Records Research and Analysis
Dudek conducted a real-time kinematic global navigation satellite system (GNSS) survey to quickly map the location of the June Lake Public Utility District (PUD) water utility infrastructure. Points were collected on the center of features, and digital photos were recorded for each feature, allowing for future asset management and creation of a comprehensive database for the water system. Dudek collected and stored the data in an Esri ArcGIS Online environment. The data was then formatted and exported to a file geodatabase. Dudek staff completed setup of the ArcGIS Online account.

Training was conducted for PUD staff on how to navigate the ArcGIS Online environment and how to conduct mobile data collection so that PUD can continue updating and managing its water utility assets in the future.

Dudek used existing National Geodetic Survey Control monuments where available. Dudek delivered the data in California State Plane Zone 3, U.S. feet, North American Datum (2011), and the vertical datum of North American Vertical Datum 1988.

DIAMOND SPRINGS COMMUNITY PARK SURVEYING SERVICES
Organization County of El Dorado
Name: Vicky Sanders,
Title: Parks Manager
Address: 330 Fair Lane, Placerville, California 95667
Phone: 530.621.7538;
Email: [email protected]
Date of Completion: 2022
Relevance to this Contract: Vertical and Horizontal Control, Topographic Surveys, Boundary Survey, Records Research and Analysis
Dudek conducted an ALTA/NSPS Land Title Survey and detailed topographic survey for a 40-acre property in Diamond Springs, California (County of El Dorado) to support future land transactions and planned land development across multiple parcels. The project required precise boundary monument retracement, extensive mapping, and integration of multiple survey methodologies to ensure comprehensive and accurate deliverables.

To achieve this, Dudek employed a combination of conventional and advanced geospatial surveying techniques.

Our field team utilized total stations and GNSS receivers to establish horizontal and vertical control, perform 














Professional Land Surveying Services 13
boundary monument recovery, and collect critical survey data. These ground-based methods ensured the highest level of positional accuracy for cadastral boundary delineation.

Additionally, Dudek leveraged UAV lidar technology to perform an aerial topographic survey, significantly enhancing data collection efficiency over the large project area. The UAV lidar data was integrated with strategically placed ground control checkpoints to validate and refine topographic accuracy. High-resolution aerial imagery was also captured to support the extraction of visible site features through aerial planimetrics, providing stakeholders with a detailed and reliable site representation for planning and design purposes. Through the application of these advanced survey techniques, Dudek delivered a comprehensive and high-accuracy mapping dataset, meeting ALTA/NSPS and project-specific requirements while supporting the client’s long-term development objectives.

BOARD OF WATER SUPPLY UTILITY MAPPING
Organization: Honolulu Board of Water Supply
Name: Ann Wong, PE
Title: Civil Engineer
Address: 630 South Beretania Street, Honolulu, Hawai’i 96843 Phone: 808.748.5448
Email: [email protected]
Period of Performance/Date of Completion: 2021–Ongoing
Relevance to this Contract: Vertical and Horizontal Control, Record Drawings, Construction Verification, Records Research and Analysis
Dudek is nearly finished supporting the Honolulu Board of Water Supplies’ (BWS) goal of increasing the positional accuracy of features in assets owned and managed by BWS. The primary mission of the project is to capture the locations (sub 30 centimeters/12 inches) of approximately 46,000 assets with centimeter accuracy. BWS provided Dudek with a GIS database of the points they needed collected. The GIS points are in general proximity of the physical asset. BWS also provided the approximate locations of assets with Unique Identifiers (ASSETCODE) and photographs of each asset. Accurate locations of assets are collected using real-time kinematic GNSS, and the asset’s unique identifier is included with the deliverable. The data collected is posted directly into ArcGIS online using Esri GNSS metadata fields, which allowed the client to view progress in real time. BWS provided access to realtime kinematic base stations for corrections. Dudek included GNSS metadata for each asset as specified by BWS.

Any uncollected assets are documented, and any missing or buried assets are identified as such. 














Professional Land Surveying Services 14
CITY OF LA CAÑADA FLINTRIDGE ON-CALL LAND SURVEYING
Organization City of La Cañada Flintridge
Name: Maged El-Rabaa
Title: City Engineer
Address: One Civic Center Drive, La Canada Flintridge, California 91011 Phone: 818.790.8882, ext. 205
Email: [email protected]
Period of Performance/Date of Completion: 2022–Ongoing
Relevance to this Contract: Vertical and Horizontal Control, Topographic Surveys, Record Drawings, Construction Verification, Records Research and Analysis
Dudek was selected by the City of La Cañada Flintridge to provide on-call surveying services. Dudek successfully conducted comprehensive topographic surveys for road improvements throughout municipal limits. Our efforts supported the City’s infrastructure projects, enabling accurate planning and execution of developments. The project entailed the detailed mapping of terrain and existing features, which were crucial for the City’s engineering and planning departments to assess and implement effective solutions for drainage, road construction, and public utility placements. Our professional team managed the project efficiently, ensuring timely delivery and highquality data that surpassed the City’s expectations.

SOUTH COAST WATER DISTRICT ON-CALL SURVEYING
Client: South Coast Water District (SCWD)
Name Taryn Kjolsing
Title: Engineering Manager
Address: 3152 West Street, Laguna Beach, California 92651 Phone: 949.499.4555
Email: [email protected]
Period of Performance/Date of Competion: 2021–Ongoing
Relevance to this Contract: Vertical and Horizontal Control, Topographic Surveys, Record Drawings, Construction Verification, Records Research and Analysis, Topographic Photogrammetry, Lidar Dudek was selected by South Coast Water District to provide on-call surveying services, successfully executing multiple task orders between 2021 and 2024. Our scope of work included installing story poles, conducting well monitoring, and performing topographic and utility surveys to support the District’s infrastructure projects.

As part of our services, Dudek provided precise survey staking for story pole installation, translating client site plans into accurately placed poles that reflected proposed build heights. Additionally, our team conducted detailed topographic and utility surveys at various reservoir sites within the District’s jurisdiction, delivering critical as-built verification data. Dudek’s responsiveness, technical expertise, and commitment to high-quality deliverables have reinforced our role as a trusted surveying partner for the District’s ongoing infrastructure and development needs. 














Professional Land Surveying Services 15
TRANSMISSION LINE SURVEY, 92-KV CA-LINE, IMPERIAL, CALIFORNIA Organization: Imperial Irrigation District (IID)
Name: Andres Avila
Title: Senior Project Manager
Address: 333 E Barioni Boulevard, Imperial, California 92251 Phone:760.482.3651
Email: [email protected]
Period of Performance/Date of Completion:: 2024–Ongoing Relevance to this Contract: Vertical and Horizontal Control, Topographic Surveys, Construction Verification, Records Research and Analysis Dudek is currently providing high-precision lidar survey and geospatial mapping services for the Imperial Irrigation District’s (IID) 92-kV CA-Line from Avenue 42 Substation to North View Substation. This project involves the integration of aerial and ground-based survey methodologies to support the detailed modeling and engineering analysis of the transmission corridor and associated substations.

To achieve comprehensive data acquisition, Dudek’s geospatial team is conducting both aerial and terrestrial field surveys to capture high-density lidar point cloud data, high-resolution orthoimagery, and video documentation of the corridor. Local survey control is being established using high-accuracy GNSS receivers and total stations, ensuring data consistency and alignment with IID’s coordinate system requirements.

Following data acquisition, Dudek’s specialized transmission line survey team will process the lidar datasets to develop a Power Line Systems—Computer-Aided Design and Drafting (PLS-CADD) plan and profile model, delivering precise transmission line analysis and clearance verification. In addition to the PLS-CADD model, Dudek will provide comprehensive survey control documentation and backup files to ensure data traceability and future usability.

Planimetric feature extraction will be performed in accordance with IID’s feature code list, ensuring all data is structured and classified per utility industry standards. Deliverables, including planimetric mapping in AutoCAD format, will be tailored to support IID’s engineering, design, and asset management requirements

NORTH VULCAN AVENUE CONDOMINIUM CONSTRUCTION STAKING
Organization: DLS Holdings LP
Name: Daniel Frye
Title: Project Manager
Address: 11723 Calle Mayor, Rancho Santa Fe, California 92067 Phone: 858.401.2292
Email: [email protected]
Date of Completion/Period of Performance: 2023–Ongoing
Relevance to this Contract: Vertical and Horizontal Control, Topographic Surveys, Record Drawings, Construction Verification, Construction Staking, Records Research and Analysis Dudek is currently performing construction staking services for a 12-unit private condominium development located at 555 and 571 North Vulcan Avenue in Encinitas, California. The scope of services includes setting two off-site and three on-site benchmarks; staking building envelopes; sewer, storm drain, water, wall, and street improvements; and additional miscellaneous survey tasks. Dudek has been successfully mobilizing to the project site within 1 day of notification to complete staking requests for the past 2 years. 














Professional Land Surveying Services 16

TRANSMISSION LINE AS-BUILT SURVEY
Organization: Southern California Edison
Name: Marco Ahumada (Beta Engineering California LP)
Title: Project Executive
Address: 9990 Mesa Rim Road #150, San Diego, California 92121 Phone: 949.241.9544
Email: [email protected]
Date of Performance/Period of Performance: December 2024– Ongoing
Relevance to this Contract: Vertical and Horizontal Control, Construction Verification, Records Research and Analysis Dudek conducted more than 600 miles of power line surveys in California via helicopter lidar operations as part of a project to determine vegetation clearances, measure line sag to verify compliance, and design new transmission lines across the state. Our team conducted surveys within 1 week to avoid the 2022 nesting season shutdown. If Dudek had not been able to mobilize survey field staff, a helicopter lidar team, and bio monitors within a week, the entire project would have been delayed a full year. The Dudek IT team accommodated the large amount of data on the team’s virtual machines and classified more than 24 billion lidar points. This project is one of the largest of its kind, showcasing Dudek as one of the few firms in North America capable of delivering projects on this scale. Our survey team installed benchmarks and ground control points for aerial data registration and tied out to the appropriate monumentation. Our GIS team developed a machine learning model to automatically classify points, which greatly reduced lidar processing time.

LAS HERMANAS ALTA/NSPS AND TOPOGRAPHIC SURVEY
Organization: Forum Mobility, Inc.

Name: Keith Slocum
Title: Project Manager
Address: 700 Mill Street, Half Moon Bay, California 94019 Phone: 805.431.884
Email: [email protected]
Date of Completion: 2023
Relevance to this Contract: Vertical and Horizontal Control, ALTA/NSPS Survey, Topographic Surveys, Record Drawings, Construction Verification, Records Research and Analysis Dudek successfully conducted an ALTA/NSPS survey in the City of Compton, California, to facilitate the land transaction of a substantial property on Las Hermanas Street. The project was delivered ahead of schedule, resulting in high client satisfaction. Field teams were on site within days of receiving the Notice to Proceed, and the client received the signed final survey within 3 weeks. In addition to the primary survey, Dudek performed several supplementary tasks, including benchmark installation, ground-based topographic surveys to support gentie design, and ortho-imagery acquisition of the surrounding area. Utilizing aerial lidar technology, Dudek derived 1-foot contours across the project site and conducted aerial target surveys for precise lidar registration.

Deliverables included a Civil 3D surface, stamped PDF ALTA/NSPS survey, and .dwg of the project site. 














Proposal for Professional Land Surveying Services 17
D. Methodology/Project Understanding
Project Understanding
The City of Diamond Bar is a vibrant suburban community in eastern Los Angeles County, known for its familyfriendly atmosphere, scenic rolling hills, and convenient access to major freeways like the SR-60 and SR-57.

Incorporated in 1989 and named after the historic Diamond Bar Ranch, the City offers a blend of rich history and modern amenities. Home to approximately 55,000 residents, Diamond Bar is celebrated for its cultural diversity, excellent schools within the Walnut Valley and Pomona Unified School Districts, and proximity to higher education institutions like Cal Poly Pomona. The city boasts numerous parks, hiking trails, and recreational facilities, including the Diamond Bar Golf Course and the Diamond Bar Center, making it a haven for outdoor enthusiasts and community events. With a strong focus on sustainability, safety, and quality of life, Diamond Bar provides a tranquil yet well-connected environment, appealing to families, professionals, and retirees alike.

The City of Diamond Bar is in the process of potentially acquiring the PONY Property, a 10-acre site located at 22601 Sunset Crossing Road, Diamond Bar, California 91765, identified by Assessor’s Parcel Numbers (APNs) 8718-005-005 and 8718-005-006, which features four unlighted baseball fields. Adjacent to this site is the Sunset Crossing Property, consisting of two vacant parcels located at 22555 Sunset Crossing Road, identified by APNs 8718-005-900 and 8718-005-901. To support the transfer of ownership and future planning, the City is seeking a qualified consulting firm to provide comprehensive land surveying services, including boundary and property line surveys and utility surveys. The Dudek team will work with the City to deliver accurate and timely data to inform maintenance and development decisions for both properties.

Project Element Scope Details
WƌŽũĞĐƚ
ůĞŵĞŶƚ ϭ͗ŽƵŶĚĂƌLJͬWƌŽƉĞƌƚLJ>ŝŶĞ^ƵƌǀĞLJ
To complete the boundary survey for the PONY Property and the Sunset Crossing Property, our team will begin with a comprehensive review of property records, deeds, recorded maps, and other relevant documents to establish a clear understanding of the existing legal descriptions and boundaries. Using this foundational information, we will perform detailed fieldwork with high-precision GNSS receivers and robotic total stations to locate and verify existing boundary markers, natural features, and site conditions. Our team will identify any discrepancies between field conditions and recorded information, ensuring alignment with legal descriptions. Permanent markers will be installed at all property corners and every 100 feet along the eastside property line of the PONY Property adjacent to homes on Big Falls Drive, as specified in the scope.

Following the field survey, we will process and analyze the collected data to produce a detailed boundary line survey map that clearly delineates property boundaries and includes accurate area calculations. The final deliverables will include signed and sealed survey maps, as well as digital copies in PDF and GIS shapefile formats, ensuring compatibility with the City’s planning and maintenance systems. By leveraging our expertise and innovative practices, we will provide the City of Diamond Bar with precise and actionable data to support the acquisition process and future decision-making for both the PONY and Sunset Crossing Properties. Under this project element, the Dudek team will accomplish the following:
ƒ Review existing property records and other relevant surveys. 














Professional Land Surveying Services 18
ƒ Perform a boundary retracement for the PONY and Sunset Crossing Properties, which includes locating and identifying existing boundary markers.
ƒ Evaluate the results of the field survey in relation to previous maps of the properties. ƒ Ensure that property boundaries are accurately aligned with existing legal descriptions and recorded documentation.
ƒ Set corners with permanent monuments at property corners and installed every 100 feet along the eastside property line of the PONY Property adjacent to the homes on Big Falls Drive. ƒ File necessary Corner Records for property corner monumentation. ƒ Draft a boundary survey map that shows the property boundaries along with area calculations.

Deliverables:
ƒ City staff will be provided with digital copies of all survey documentation created, including the survey map in a PDF, .dwg, or any GIS file type requested. The City will be provided with all reference documentation used to create the surveys.

Assumptions:
ƒ Based on our intial research, a Record of Survey (ROS) is not required. An ROS might be necessary upon review of the field boundary retracement.

WƌŽũĞĐƚ
ůĞŵĞŶƚϮ͗hƚŝůŝƚLJ^ƵƌǀĞLJ
Dudek and our teaming partner Ground Penetrating Radar Systems Inc. will provide underground utility locating services, as described in the following subtasks.
dĂƐŬϮ͘ϭhŶĚĞƌŐƌŽƵŶĚhƚŝůŝƚLJ>ŽĐĂƚĞ
The first step in engineering design of the project components is to develop a full set of accurate and utility data and a thorough understanding of existing as-built utility environment. The underground utility locate for the PONY Property and the Sunset Crossing Property will be performed using advanced technologies and a thorough methodology to ensure comprehensive identification of all underground utilities. The scope of work involves locating and marking utilities across the designated 13.01-acre area using visible surface features, such as structures and access points, as initial indicators. Utilities will be marked on the surface using paint, pin flags, or other appropriate methods to facilitate further analysis and mapping. To enhance the accuracy of the utility locate, the client is requested to provide drawings or notify the team of utilities not visible from the surface, and the work area should be pre-cleared of obstructions before fieldwork begins.

To execute the underground utility locate, Ground Penetrating Radar Systems Inc. will employ state-of-the-art equipment, including ground-penetrating radar (GPR) antennas, electromagnetic pipe locators, traceable rodders, robotic crawler cameras, sondes, and GPS units. The robotic crawler camera, equipped with modular wheels and live video capabilities, will inspect pipes with diameters of 8 inches and greater. It features a sonde that transmits signals to determine pipe locations and depths up to 10 feet, even in challenging conditions. The GPR system will identify both metallic and non-metallic utilities to depths of up to 8 feet, while the electromagnetic pipe locator will trace signals along metallic pipes or tracer wires. The traceable rodder and sonde will locate pipes at depths up to 15 feet, with signals detectable from the surface. Finally, the GPS unit will document utility locations with precision down to 4 inches, exporting data compatible with GIS and CAD platforms. This thorough, technology-driven approach will provide the City of Diamond Bar with the critical data necessary for effective planning and management. 














Professional Land Surveying Services 19
dĂƐŬϮ͘ϮhƚŝůŝƚLJZĞƐĞĂƌĐŚ
To ensure a comprehensive and accurate utility survey for the PONY Property and the Sunset Crossing Property, our team will begin by conducting a thorough review of existing utility maps and public records from local utility companies and relevant agencies. This research phase is critical to establishing a detailed understanding of the existing utility infrastructure, including both aboveground and underground systems. The Dudek team will also utilize CivilGrid software to conduct our utility research. CivilGrid software will be used to streamline and enhance the planning and design processes by aggregating the site utility data in a single geospatial data form.

Our process will include formally reaching out to local utility providers to request as-built drawings, utility maps, and any available records associated with the subject parcels. We will utilize our established relationships with utility companies to facilitate the efficient acquisition of these documents and coordinate any necessary site visits or consultations. Additionally, we will review public records from City and County archives, such as permit records and utility easement documents, to identify any utilities not covered in the available maps. Once gathered, this information will be cross-referenced with on-site findings to ensure accuracy and identify potential discrepancies between recorded data and field conditions. The result will be a well-documented utility framework that forms the foundation of the subsequent survey and mapping efforts.

Utility features to be mapped include, but are not limited to, water, sewer, gas, electric, and telecommunications.

The survey map will include above- and belowground utilities, including valve locations, and distinguish between utility types, locations, depths, and conditions.

Deliverables:
ƒ City staff will be provided with digital copies of all survey documentation created, including the survey map in a PDF, .dwg or any GIS file type requested. The City will be provided with all reference documentation used to create the surveys.

WƌŽũĞĐƚ
ůĞŵĞŶƚϯ͗WƌŽũĞĐƚDĂŶĂŐĞŵĞŶƚ
Effective project management is critical to project success. As a medium-sized firm, we provide the personal service of project managers combined with the breadth and depth of technical capabilities characteristic of larger firms to meet the City’s project requirements. Our project managers are empowered to be problem solvers with the ability to make decisions in a timely fashion to maintain project momentum.

Project Manager Ryan Shupert will oversee the timely completion of this scope of work to the satisfaction of the City and applicable permitting regulatory agencies. Ryan will serve as the liaison to the City’s project coordinator and provide regular updates on task completion, deliverables, and budget. Project management under this element includes general open correspondence between involved parties as well as specific tasks, such as attending project meetings, invoicing, etc. The following project management services will be provided at a minimum:
ƒ Attend project kickoff meetings.
ƒ Attend team meetings to review survey progression with City staff. ƒ Coordinate site access and necessary permissions for field personnel. ƒ Notify City staff of any issues that have the possibility of affecting the schedule or budget of the project as soon as they occur.















Professional Land Surveying Services 20
WZK:
d^&
dz
Safety Program
The Dudek survey team takes safety very seriously and strictly follows the Survey Safety Plan that was developed by our company safety officer. To manage and mitigate the risk of any incidents, the survey team is required to follow safety procedures for all survey scopes that include risk assessments, safety briefings, and daily equipment inspection protocols. In addition to following daily safety protocols, Dudek has a third-party safety audit team that performs random inspections of active field activities so that they comply with personal protective equipment and safety protocols. Dudek routinely reviews field staff motor vehicle records for infractions and accidents. These requirements are all designed to reduce risk and have been a key part of Dudek’s emphasis on field safety. A fulltime safety and health program coordinator ensures that our program complies with federal, state, and local regulations, meeting all occupational safety and health requirements, and bridging the gap between compliance and excellence. Dudek staff understand and respect the diverse environments and conditions in which we operate. We believe that all work-related injuries and illnesses are preventable, and we encourage reporting of all health and safety hazards, incidents, and near misses to avoid negative outcomes. Additionally, many of our staff are CPR- and first aid-certified, providing a second line of defense against unforeseeable health events.

Injury and Illness Prevention Plan. The Dudek comprehensive Injury and Illness Prevention Plan (IIPP) encompasses all Dudek service offerings. Our IIPP includes a Code of Safe Practices, hazards analysis, accident reporting and investigation procedures, recordkeeping requirements, and all applicable safety programs. Our comprehensive IIPP exemplifies our dedication to keeping our employees safe. No accidents on the job means no time lost and no money wasted.

ISNetworld. Dudek is an active member of ISNetworld, which provides clients a streamlined reporting dashboard for verifying Dudek insurance certificates; Occupational Safety and Health Administration (OSHA) forms; Experience Modification Rate letters; health, safety, and environmental programs; and training information. We save clients time by providing third-party verification that our programs are of the highest caliber. Our integration with ISNetworld also allows clients to use the portal to submit monthly reports on hours spent on a project or number of incidents, if any, in accordance with OSHA recordkeeping requirements.

Gold Shovel Standard Certified. Gold Shovel Standard Certification is a widely recognized indication of increased safety awareness and a commitment to continuous damage prevention improvement. Excavators within Gold Shovel Standard rely on Gold Shovel Standard technology to measure safety and efficacy and can present hard data to support their reputation. The Dudek Gold Shovel Standard Certification demonstrates our commitment to high safety standards and tracking the progress of high-risk activities like archaeological excavation and monitoring. Partnering with the Gold Shovel Standard Community allows Dudek to work efficiently and safely while simultaneously reducing damage prevention.

WZK:
d/DW>
D
Edd/KEE
>/s
Zz
Figure 2 outlines the Dudek project delivery process for surveying and mapping services. 














Professional Land Surveying Services 21
Figure 2. Project Delivery Process
The project management philosophy for this contract is based on lessons learned from 20 years of mapping and survey projects. The Dudek team makes decisions that enable continuous forward project momentum. The team’s proven project management approach is based on the following project life cycle process:

Project Scoping. Dudek ensures clear communication with the client team to define the project scope of work so both parties have a common understanding of the project goals and objectives. The Dudek project manager will establish preliminary schedules, draft the work plan, and budget during this phase.

Work Plan Development. Following the approval of the project scope, the Dudek team will create a work plan to define how the survey is completed efficiently and accurately. The work plan will contain the project scope and background, along with a detailed schedule outlining the time expectations for each team member. This process provides clear expectations for the team, which in turn guarantees that District projects are completed within the allotted time and on budget.

Safety Plan Development. The Dudek survey team will work in collaboration with our internal Environmental Health and Safety team to review the project and determine risks associated with the work. Protocols are determined and actionable risk mitigation steps are implemented to decrease the risk of injuries. This plan is essential for the health and well-being of Dudek field staff and contributes significantly to the progression of the project.

Data Collection. After defining the work and safety plan, Dudek will mobilize the team to complete the ground data collection to support the scope of services for each task order. Our field teams are led by highly experienced field surveyors who provide daily updates on fieldwork progression. Progression updates from the field are then provided to the District, allowing staff to have a clear view of where each task stands.

Post-Processing. After the data has been collected in the field, the Dudek office team will calibrate the data and complete the required post-processing to create the final deliverables.

Data Analysis. The Dudek team will complete the required analysis of the collected, calibrated, and processed data and will document the methods and procedures used to complete the deliverables. This will include the equipment used, names of staff members, mathematical computations, accuracy of the data collected, horizontal and vertical datums, and project control points with descriptions.

Data Dissemination. The Dudek team will deliver the final products by disseminating them to the client via the appropriate channels. Dudek utilizes ShareFile to seamlessly transfer large deliverable files. 














Professional Land Surveying Services 22
Continuous Communication
Our project manager places a high priority on a continuous flow of information, data, instructions, and guidance.

We are committed to engaging in clear communication and cooperation with the City, holding regular conference calls, and preparing agendas to assist teams in clarifying any issues and proceeding with the work in a unified manner. We use check-in meetings with our project teams to allocate resources properly and according to the City’s schedule constraints. When working on several concurrent projects, we identify areas where information sharing can reduce the time, budget, and/or work needed to produce deliverables. We will maintain regular communication with the City via the following practices:
ƒ Utilizing an Esri-based portal system for clients to view project status, live updates, and deliverables as they are being completed, which will allow the City to view deliverable creation in real time ƒ Scheduling regular calls and check-ins with the City’s key contact to discuss milestones, activities, and potential issues
ƒ Holding regular project management meetings with key staff (including other consultants, as applicable) to coordinate work efforts, monitor task completion, and review budget conformance ƒ Updating, as necessary, the project description, schedule, work progress reports, and inventories of available data so that all team members are aware of information that may affect their work products and schedules ƒ Coordinating with District staff at strategic junctures for public input Cost and Schedule Control
Dudek is committed to maintaining continuous communication and closely monitoring cost and schedule performance. Using the latest available digital project management systems, we maintain accurate, up-to-date budgets and schedules. We can share cost and schedule details with the City in real time by efficiently and accurately tracking budgets and regularly updating project schedules.

Responsiveness
Because Dudek is a medium-sized firm, we can respond quickly in both the field and office to fulfill the City’s timelines while utilizing the latest land surveying technologies offered by larger firms. Dudek prides itself in the rapid deployment of field teams to a project site to meet the City’s needs. Dudek has strategically placed field teams within the vicinity of the City’s extents to respond within a day for task orders. The City can expect quick replies, answers, and recommendations from Dudek via phone, email, and video calls to assist in project progression.

Quality Assurance/Quality Control
Dudek’s quality assurance/quality control (QA/QC) program is designed to ensure accuracy, consistency, and reliability in all project deliverables through senior staff oversight and dedicated administrative management. Our commitment to quality extends across every stage of the process, emphasizing precision and adherence to the required mapping and survey accuracy tolerances. To maintain these high standards, Dudek employs a comprehensive five-step QA/QC process:

1. Planning and Preparation: To ensure the success of the project, clear objectives, scope, and accuracy standards are established at the outset. Survey equipment is carefully selected and calibrated to guarantee precision and reliability. Control points are identified, marked, and verified to provide a solid 














Professional Land Surveying Services 23
foundation for data collection. Prior to fieldwork, the survey crew is thoroughly briefed on project procedures, safety protocols, and quality expectations, ensuring alignment and preparedness.

2. Field Data Collection: During field operations, instruments are regularly checked and calibrated to maintain accuracy. Redundant measurements are taken to verify data reliability, while all observations are meticulously recorded with clarity and completeness. Field checks are conducted on critical points to confirm the precision of measurements. Any unusual conditions or potential sources of error encountered in the field are documented to provide context and ensure transparency in the data collection process.

3. Data Processing and Analysis: Once collected, raw data is carefully processed and analyzed for inconsistencies or errors. Advanced data analysis software is utilized for calculations, transformations, and adjustments, ensuring the highest level of accuracy. The processed data is rigorously reviewed for inconsistencies or anomalies, with validation performed by comparing results against known control points or established benchmarks to confirm its integrity.

4. QC Checks: To uphold quality standards, all collected data undergoes an independent review by a qualified surveyor. Critical calculations are double-checked for accuracy, and random spot checks are performed on field measurements to identify potential errors. The survey results are then compared against existing records or project specifications to ensure that they meet the required standards of accuracy and consistency.

5. Final Review and Certification: All survey procedures, observations, and calculations are clearly documented to create a comprehensive record of the project. QA/QC processes, findings, and any corrections applied are included in the final survey report for full transparency. Detailed project records are meticulously maintained to support future reference, compliance, or audit needs.

This meticulous QA/QC process enables Dudek to consistently deliver high-quality surveying and mapping products that align with client expectations and project objectives. 














Proposal for Professional Land Surveying Services 24
E. Cost for Services
Dudek’s detailed not-to-exceed cost proposal and hourly rates are provided on the following pages for the City’s review. 














Project Team Role:

Survey Crew
Chief
CADD Operator
II CADD Drafter Survey Lead Survey Manager
Underground Utility
Locate
Team Member: James Bocina Gregory Mata Mark Hudi Hunter Stetson Ryan Shupert Ground Penetrating
Radar Systems, Inc
Billable Rate: $140.00 $120.00 $120.00 $190.00 $190.00 Fee Task 1 PONY Property

1.1 Boundary/Property Line Survey

1.1.1 Property Records Research 4 4 $760.00 $760.001.1.2 Boundary Drafting 16 2 18 $2,300.00 $2,300.001.1.3 Field Boundary Retracement 16 16 $2,240.00 $410.00 $2,650.001.1.4 Corner Setting/Corner Records 16 16 2 34 $4,540.00 $410.00 $4,950.001.1.5 Project Management 1 1 $190.00 $190.00

1.2 Utility Survey

1.2.1 Utility Research 2 2 $380.00 $380.00

1.2.2 Underground Utility Locate $6,000.00 $6,000.00

1.2.3 Utility Drafting 8 8 $960.00 $960.001.2.4 Project Management 1 1 $190.00 $190.00 Subtotal Task 1 32 16 24 10 2 84 $11,560.00 $820.00 $18,380.00 Task 2 Sunset Crossing Road Property

2.1 Boundary/Property Line Survey

2.1.1 Property Records Research 2 2 $380.00 $380.002.1.2 Boundary Drafting 8 2 10 $1,340.00 $1,340.002.1.3 Field Boundary Retracement 8 8 $1,120.00 $205.00 $1,325.002.1.4 Corner Setting/Corner Records 8 8 2 18 $2,460.00 $205.00 $2,665.002.1.5 Project Management 1 1 $190.00 $190.00

2.2 Utility Survey

2.2.1 Utility Research 2 2 $380.00 $380.002.2.2 Underground Utility Locate $3,435.00 $3,435.002.2.3 Utility Drafting 8 8 $960.00 $960.002.2.4 Project Management 1 1 $190.00 $190.00 Subtotal Task 2 16 8 16 8 2 50 $7,020.00 $410.00 $10,865.00 Total Hours 48 24 40 18 4 134
Total $6,720.00 $2,880.00 $4,800.00 $3,420.00 $760.00 $18,580.00 $9,435.00 $1,230.00 $29,245.00 Percent of Hours (Base) 36% 18% 30% 13% 3%

TOTAL FEE
Dudek Labor Hours and Rates Subconsultant Fees
TOTAL

DUDEK HOURS

DUDEK LABOR
COSTS

OTHER DIRECT
COSTS
Ϯϱ
Proposal for Professional Land Surveying Services















Proposal for Professional Land Surveying Services 26
F. Insurance
Dudek has reviewed the insurance requirements and confirms that our insurance meets all the requirements. If selected, Dudek and our subconsultant partner will submit proof of insurance and a “Statement Certifying Insurance Coverage” to the City.















Proposal for Professional Land Surveying Services 2
G. Consulting Services Agreement
Dudek has reviewed the Consulting Services Agreement and proposes the following edits for the City’s consideration:
ƒ Section 4C: We suggest striking the retainage language as follows: “,but may withhold 30% of any invoice until all work is complete, which sum shall be paid within 35 days of completion of the work and receipt of all deliverables.”
ƒ Section 9: We suggest adding language to the end of the section as a new paragraph as follows:
"Notwithstanding the foregoing, with respect to any professional liability claim or lawsuit, this indemnity does not include providing the primary defense of City, provided, however, Consultant shall be responsible for City’s defense costs to the extent such costs are incurred as a result of Consultant’s negligence, recklessness or willful misconduct."
ƒ Section 15: We suggest the following language be added to the end of the section: “Consultant may stop work and/or terminate this Agreement upon 10 days’ written notice to City in the event City is in breach of any provision of this Agreement, and City fails to cure such breach during such 10-day period.” ƒ Section 20: We suggest striking this section.















Appendix A
Resumes















1 Steven Hochart

PRINCIPAL-IN-CHARGE
Steven Hochart is a project manager with 23 years’ mapping and surveying consulting experience. Steven connects a diverse range of clients, including private companies, cities and counties, universities, and the military with the right mapping/surveying solutions to enhance project operations. He has managed various projects ranging from mapping/survey to database/system implementation and feasibility studies to vegetation and stream mapping, species modeling, and reserve planning.

Additionally, Steven has extensive experience in IT and strategic master planning, compliance monitoring, land use permitting, and GIS analysis and mapping. He has managed large on-call contracts for state, municipal, and federal agencies across multiple lines of services for a diverse set of clients.

Relevant Project Experience
Development
UAV-Based LiDAR and Aerial Imagery Data Collection, Private Developer, El Centro, California. Responsible for all aspects of project coordination and management of the project. Dudek was responsible for planning and collecting UAV-based LIDAR and aerial imagery for the El Centro project site. Project planning included coordinating with local FAA and obtaining the required permissions to fly the project site. After the UAV data was collected for the project site, the Dudek team completed all of the data post-processing and developed the final deliverables. The final deliverables included orthophoto, topo contours, site planimetrics, and site perspective views. All deliverables were completed and delivered with under 1-inch positional accuracy.

UAV-Based LiDAR and Aerial Imagery Data Collection, Alexander & Baldwin, Maui, Hawaiʻi. Responsible for all aspects of project coordination and management of the project. Dudek was responsible for planning and collecting UAV-based LIDAR and aerial imagery for the Industrial Lot project site. Project planning included coordinating with local FAA and obtaining the required permissions to fly the project site. After the UAV data was collected for the project site, the Dudek team completed all of the data post-processing and developed the final deliverables. The final deliverables included orthophoto, topo contours, site planimetrics, and site perspective views. All deliverables were completed and delivered with under 3-inch positional accuracy.

Municipal
City and County of Honolulu Fire Department Asset Management Design and Implementation, Hawaiʻi. As project manager/technology lead, was responsible for working with all project stakeholders in the City and County of Honolulu Fire Departments to create the first map-based asset management system for the city. The system was integrated with ESRI ArcServer and IBM Maximo platforms. The results enabled the fire department to view the location of all assets on the island of Oʻahu.

Education
University of California,
Santa Barbara
BA, Geography,
(Environmental Studies
emphasis), 2001















2 IBM Maximo Implementation with Custom Mapping Application, City and County of Honolulu, Hawaiʻi. As project manager, was responsible for the implementation of the Maximo Asset Management System for the City and County of Honolulu. Managed the implementation team and was responsible for customer communication with all project stakeholders throughout the process of implementing the new system for the client. The final system utilized IBM’s Maximo Asset Management system and a custom Environmental Systems Research Institute (ESRI) interface that enabled the users to create and process work orders using a custom map interface.

Pavement Management System Implementation, City and County of Honolulu, Hawaiʻi. As project manager/ technology lead, was responsible for working with the project stakeholders to identify the requirements for a new pavement management system that would be used to plan for future capital improvement projects. Steven then developed a technology solution for the city and county that met their requirements by using a suite of different “off the shelf” software solutions.

Super Ferry Feasibility Study, State of HawaiʻiHarbor Division, Honolulu, Hawaiʻi. Served as project lead/ geographic information system (GIS) analyst. Responsible for creating an infrastructure inventory for all of the harbors in the state of Hawaiʻi and creating a feasibility model to identify the harbors with highest suitability for accommodating the Hawaiʻi Super Ferry.















1 Ryan Shupert

PROJECT MANAGER
Ryan Shupert is a survey manager with 5 years’ experience managing geospatial and land survey projects throughout North America and Hawai‘i for utility providers, renewable developers, due diligence firms, and local municipalities. Ryan’s experience includes ALTA/NSPS surveys, civil design topographic surveys, utility surveys, transmission line surveys, easement exhibits, aerial lidar, and photogrammetry.

Project Experience
Water Infrastructure GIS Asset Mapping, June Lake Public Utility District, June Lake, California. Served as project manager for the real-time kinematic survey to map the location of the June Lake Public Utility District water infrastructure.

Points were collected on the center of features, and digital photos were recorded for each feature, allowing for future asset management and creation of a comprehensive database for the water system. Dudek collected and stored the data in an Esri ArcGIS Online environment. The data were then formatted and exported to a file geodatabase. Dudek staff completed setup of the ArcGIS Online account. Training was conducted for Dudek’s Planning and Urban Design staff on how to navigate the ArcGIS Online environment and how to conduct mobile data collection so that staff can continue updating and managing their water utility assets in the future. Dudek used existing National Geodetic Survey control monuments where available. Dudek delivered the data in California State Plane Zone 3, U.S. feet, North American Datum of 2011, and North American Vertical Datum of 1988.

Water Infrastructure GIS Asset Mapping, Board of Water Supply, Oahu, Hawai‘i. Served as field operations manager for the GIS mapping of approximately 46,000 water assets throughout the island of Oahu. Accurate locations of assets were collected using real-time kinematic GNSS, and the asset’s unique identifier was included with the deliverable. The data collected were posted directly into ArcGIS Online using Esri GNSS metadata fields, which allowed the client to view progress in real time. The project was challenging due to the number of assets that needed to be mapped, so a large field crew was organized to complete the fieldwork ahead of schedule.

Civil Design Topographic Surveys, City of La Canada Flintridge Engineering Department, La Canada Flintridge, California. Served as project manager for a 2-mile topographic survey for design purposes by the city engineer.

This project required the use of total stations necessary to achieve the high levels of accuracy required for design.

Several right-of-way permits were required to be filed and traffic control was organized for safety purposes.

Reservoir 5B Topographic Survey, South Coast Water District, Dana Point, California. Served as project manager for a civil design topographic survey for a reservoir maintained by the South Coast Water District. The data were utilized by project engineers for the design and replacement of the reservoir.

Education
Liberty University
BS, Aeronautics
(Unmanned Aerial
Systems emphasis)
Certifications
FAA Remote Pilot
Certification, Part 107,
Small Unmanned Aircraft,
2016, No. 3940189
Private Pilot, Airplane
Instrument Rating,
No. 3858922
North Carolina DOT UAS
Commercial Operator
Permit, 2023,
No. C0018405
Transport Canada Small
Remotely Piloted Aircraft
System, Visual Line of Site,
Basic Operators, 2024,
No. PC2305318756















2 Owen’s Lake Aerial Lidar Survey for Dust Mitigation, Los Angeles Department of Water and Power, Lone Pine, California. Served as project manager for the quarterly lidar data collection for the Owen’s Lake dust mitigation project. This project required Notices to Air Missions to be filed with the Federal Aviation Administration in accordance with client requirements as the subject area falls within military aviation training routes. Permanent control was established on site to serve as the basis for each quarter’s data collection.

Fort Shafter and Schofield Barrack ALTA/NSPS Surveys, Confidential Client, Honolulu, Hawai‘i. Served as project manager for two ALTA/NSPS surveys conducted on U.S. Army land. Boundary retracement posed especially difficult due to the lack of previously recorded surveys of the subject parcels. Coordination and approval to access the lands was required to be performed through the Department of Defense to complete the fieldwork.

Task Order 6, State of Hawai‘i, Department of Hawaiian Homelands, City of Kawaihae, Hawai‘i. Served as remote pilot in command for the collection imagery to generate a geo-referenced orthomosaic image for 7,000 acres of development land. These data were utilized as a baseline for land development projects by the Department of Hawaiian Homelands. The remoteness and terrain of this project required extensive planning and coordination to ensure data collection was conducted safely and effectively.

Task Order 9, State of Hawai‘i, Department of Hawaiian Homelands, City of Kahikinui, Hawai‘i. Served as remote pilot in command for the collection imagery to generate a geo-referenced orthomosaic image for 4,000 acres of development land. These data were utilized as a baseline for land development projects by the Department of Hawaiian Homelands.















1 Armando Magana, PE, LS

PROFESSIONAL LAND SURVEYOR
Armando Magana is a civil engineer with 28 years’ experience in the public and private sectors in the Coachella Valley. Armando’s license as a land surveyor complements his engineering abilities by allowing him to be involved in a wide variety of design elements thoughout the land development process and to provide technical assistance to resolve any conflicts that may arise during construction. Armando has a solid foundation as a hydrologist and is able to develop extensive, varied, and appropriate drainage solutions.

Armando served as engineer in charge and the contracting officer’s technical representative at the Marine Corps Air Ground Combat Center in Twentynine Palms, California. His experience includes coordinating the design, maintenance, and repair of utility infrastructure, including water and sewer lines, roads, culverts, and surface drainage structures, and developing construction drawings and specifications for civil engineering systems, such as sewer mains, storm and sanitary sewer lines, parking lot and road repaving, and other similar projects.

Project Experience
The Presidents Club at Indian Palms, Indio, California. Provided construction staking calculations for sewer main, water main, curb and gutter, building layout and location, wall, parking lot, and storm drain staking.

Various Projects, Various Locations. Crew party chief during field work. Produced tract maps, parcel maps, records of surveys, American Land Title Association (ALTA) surveys, lot line adjustments, parcel mergers, and easement documents with legal descriptions.

American Kings, First Solar Development, Lemoore, California. Prepared a topographic base map for 1,570 acres located to the northeast of the intersection of Avenal Cutoff Road and 25th Avenue. Reviewed and compared spot elevations with contours to verify that vertical accuracy is in compliance with the national map accuracy standards.

Jamestown, Rural County Representatives of California, La Grange, California. Prepared a topographic base map for 90 acres located at 12001 La Grange Road, La Grange, California 95329. Reviewed and compared spot elevations with contours to verify that vertical accuracy is in compliance with the national map accuracy standards. Obtained data for site development and design, including boundaries, elevations, and topographic features visible on the ground surface, such as flat areas, roads, embankments, changes in grades, swales, ditches, tree outlines, structures, and ponds. Determined and recorded the size, direction of flow, material of construction, and routing of all underground utilities using existing drawings verified by observation within manholes, location of valves and hydrants, and pipe or conduit above ground. All existing structures, equipment, foundations, railroad switches, utility infrastructure, and other similar features were located and tagged with point data or reference notes. Contour lines were shown at 1-foot vertical intervals. Contours were drawn clear and sharp, using dashed lines, with every fifth contour (5-foot interval) bold/accentuated.

Education
California Polytechnic
State University,
San Luis Obispo
BS, Civil Engineering,
1995
Certifications
Professional Civil
Engineer (PE),
CA No. 59563
Licensed Land Surveyor
(LS), CA LS 8232















2 White Rock, D.E. Shaw Renewable Investments, Sacramento, California. Prepared a topographic base map for 3,450 acres located to the north of the intersection of Scott Road and Boys Ranch Road. Reviewed and compared spot elevations with contours to verify that vertical accuracy is in compliance with the national map accuracy standards.

Battery Energy Storage System, Eolus Project Holdings LLC, Poway, California. Prepared an ALTA for lots 29, 30, and 31 City of Poway Tract 87-13 Unit 1 Map No. 12556. Reviewed title report and plotted easements of record, located existing structures and utilities, and certified that the map/survey was in accordance with the Minimum Standard Detail Requirements for ALTA/NSPS Land Title Surveys adopted by ALTA and National Society of Professional Surveyors (NSPS) in 2021 and included items 2, 3, 4, 8, 9, 11(A), 11(B), and 13 of Table A.

Captiva, Broad Reach Power, San Capistrano, California. Prepared an ALTA for 29343 Camino Capistrano, San Capistrano, California 92675. Reviewed title report and plotted easements of record, located existing structures and utilities, and certified that the map/survey was in accordance with the “Minimum standard detail requirements for ALTA/NSPS land title surveys” adopted by ALTA and NSPS in 2021 and included items 1, 2, 3, 4, 8, 9, 6(A), 6(B), 8, 11, 13, 14, 16, 17, and 20 of Table A.

Coachella Valley Mosquito and Vector Control District, Indio, California. Served as senior civil engineer. Prepared a Tentative Tract Map 38680 for 15 lots located near Trader Place and Oleander Ave, Indio, California 92201.

Coordinated with the environmental department to prepare a CEQA Initial Study. Plotted record easements on the map. Tentative Tract Map 38680 was approved by the City and condition of approval for the final tract map was provided.















1 Stephen Paul, PLS

PROFESSIONAL LAND SURVEYOR
Stephen Paul is a project manager with 41 years’ experience as a land surveyor specializing in boundary, topographic, ALTA/NSPS land title surveys, GPS, construction stakeout, subdivision and development projects, water, sewer and other utilities and infrastructure improvement projects. He has worked with public-sector clients at the local, state, and federal levels, as well as private sector clients.

Relevant Previous Experience
Development
Castle & Cooke Homes Hawaii, Mililani Mauka Offsite Roadways, Phase 11, Topographic Survey after erosion repair. Senior land surveyor and project manager who prepared an as-built topographic survey of a repaired erosion area for comparison to the original grading plan.

Castle & Cooke Homes Hawaii, Mililani Mauka Rear Property Line Encroachment Surveys II. Senior land surveyor and project manager who oversaw surveys that showed encroachments onto community-owned firebreak lots by private lot owners.

Castle & Cooke Homes Hawaii, Koa Ridge Offsite Drainage Topographic Surveys.

Senior Land Surveyor and project manager who prepared topographic surveys for the design of offsite storm drainage system for a large residential development.

Forest City Commercial Development, Increment IV, Navy Family Housing PPV II.

Various locations on Oahu, senior land surveyor who provided ALTA/ACSM land title surveys, land court and regular system boundary surveys, as well as topographic mapping of military housing neighborhoods totaling over 200 acres.

SamKoo Pacific, LLC, The Central Ala Moana and Kapiolani Residence. Senior land surveyor and project manager who provided boundary and topographic surveys, construction stakeout services, and ALTA/NSPS Land Title surveys for the design and construction of two high-rise developments in downtown Honolulu, Hawaii.

Kyo-Ya Company, LLC, Royal Hawaiian and Sheraton Waikiki Hotels. Senior land surveyor and project manager who prepared ALTA/NSPS Land Title surveys for two resort complexes in Waikiki, Hawaii.

Water/Wastewater
City and County of Honolulu Board of Water Supply, Ekoa Place and Mona Street Rockfall Mitigation, Aina Haina, Honolulu, Hawaii. Senior land surveyor who prepared topographic maps of an area on a steep hillside behind approximately 20 private residences.

Education
North Carolina Society of
Surveyors Institute at
North Carolina State
University, Raleigh,
North Carolina
Certificate of Graduation,
Specialized Surveying
Curriculum, 1996
Certifications
Professional Land
Surveyor (PLS), HA No. LS12526
Registered Land Court
Surveyor, HA No. 370
PLS, Guam No. 079
PLS, NC No. L3340















2 City and County of Honolulu Board of Water Supply, Makakilo Water System Improvements, Part III, Kapolei, Honolulu, Hawaii. Senior land surveyor and project manager who prepared topographic surveys for the preparation of plans and specifications to replace approximately 11,400 linear feet of four-, six-, and eight-inch water mains and appurtenances in Makakilo.

City and County of Honolulu Board of Water Supply, Fire Hydrant Installations at Aiea and Kaimuki, Honolulu, Hawaii. Senior land surveyor and project manager who prepared topographic surveys for the preparation of plans, specifications, cost estimates, and permits for the installation of 23 fire hydrants.

City and County of Honolulu Board of Water Supply, Storm Water Management Plan Improvements, Honolulu, Hawaii. Senior land surveyor and project manager who prepared topographic surveys to prepare plans, specifications, cost estimates, and permits for proposed improvements to storm water discharge at 4 BWS sites on Oahu.

City and County of Honolulu Board of Water Supply, Kapolei Base Yard and Desalination Plant Master Plan, Kapolei, Honolulu, Hawaii. Senior land surveyor and project manager who prepared topographic surveys for planning, engineering, and architectural services to redevelop the property.

City and County of Honolulu Board of Water Supply, Service Lateral Replacement at Mililani, Honolulu, Hawaii.

Senior land surveyor who prepared boundary and topographic surveys for the design and construction of service lateral replacements.















1 Hunter Stetson

PROJECT MANAGER
Hunter Stetson has 12 years’ surveying experience in the Bay Area and Northern California performing a wide range of roles, from chainman to project surveyor, at many large firms. Hunter’s expertise spans topographic, ALTA/NSPS, boundary, construction staking, monitoring, control networks, level loops, corner records, monument preservation, and hydrographic surveys, handling both office and field scopes. Specializing in conventional survey techniques and newer technologies such as remote sensing and terrestrial scanning, Hunter is proficient in programs such as Civil 3D (2012-2024), Trimble Business Center, Leica Infinity, Cyclone, Starnet, Mission Planner, HyPack, Drone Deploy, Pix4D, Bluebeam, and MS Office. Additionally, Hunter is experienced with drones including the Wingtra Gen 2, DJI Phantom 4 Pro, and Seafloor Systems Hydrone, providing clients with a wide range of options to complete a survey.

Project Experience
ALTA/NSPS Survey, Confidential Client, 2800 Sand Hill Road, Menlo Park, California͘Served as surveyor of record for an ALTA/NSPS survey of a multi-building office complex in Menlo Park, California. Managed field crews and provided them with pre-calculations for boundary recovery, features that needed to be surveyed to comply with client provided Table A list, directed field crew on control tie ins and safety procedures. Conducted site verification and provided ortho-rectified aerial imagery of the project site utilizing the Phantom 4 Pro.

Hinman Dam Topographic and Hydrographic Survey, California Department of General Services, Yountville, California. Served as surveyor of record for a 3.5-acre hydrographic survey of the reservoir bed. Provided UAV photogrammetry of surrounding environment for additional analysis. Conducted traditional topographic survey utilizing conventional survey techniques with GNSS systems and total stations.

Cobb Mountain CHP Tower Topographic and Boundary Survey, California Department of General Services, Cobb Mountain, California. Served as surveyor of record for a topographic and boundary survey for a CHP tower lease.

Utilized unmanned aircraft systems to conduct an ultra-high detailed LiDAR topographic survey for 5 miles of access roads. Conducted traditional topographic survey utilizing conventional survey techniques with GNSS systems and total stations. Provided the client with an unrecorded rights report and corrected easements were provided.

ALTA/NSPS Survey, Confidential Client, San Juan Capistrano, California. Currently serving as surveyor of record for an ALTA/NSPS survey for a large real estate transaction supporting the renewable energy sector. This project posed significant challenges determining a boundary resolution due to the lack of mapping and inaccuracies in existing maps. A multitude of easement exhibits both permanent and temporary in nature were created to support the project development. Additional tasks included reviewing field data, research previous surveys, and determining boundary resolutions.

GPS Survey Control Network, Confidential Client, Northern California. Served as surveyor to provide the client with a comprehensive GPS control network for 35,000 miles of transmission lines. These controls were utilized to register helicopter LiDAR data for an as-built survey. Managed and directed field teams to safely obtain GPS observations. Coordinated and made recommendations to the client on optimal control locations with consideration for location, environment and safety.

Education
CSU Fresno,
Bachelor of Science in
Geomatic Engineering,
2018
Certifications
California Professional
Land Surveyor #9737















2 Water/Wastewater
City and County of Honolulu Board of Water Supply, Ekoa Place and Mona Street Rockfall Mitigation, Aina Haina, Honolulu, Hawaii. Senior land surveyor who prepared topographic maps of an area on a steep hillside behind approximately 20 private residences.

City and County of Honolulu Board of Water Supply, Makakilo Water System Improvements, Part III, Kapolei, Honolulu, Hawaii. Senior land surveyor and project manager who prepared topographic surveys for the preparation of plans and specifications to replace approximately 11,400 linear feet of four-, six-, and eight-inch water mains and appurtenances in Makakilo.

City and County of Honolulu Board of Water Supply, Fire Hydrant Installations at Aiea and Kaimuki, Honolulu, Hawaii. Senior land surveyor and project manager who prepared topographic surveys for the preparation of plans, specifications, cost estimates, and permits for the installation of 23 fire hydrants.

City and County of Honolulu Board of Water Supply, Storm Water Management Plan Improvements, Honolulu, Hawaii. Senior land surveyor and project manager who prepared topographic surveys to prepare plans, specifications, cost estimates, and permits for proposed improvements to storm water discharge at 4 BWS sites on Oahu.

City and County of Honolulu Board of Water Supply, Kapolei Base Yard and Desalination Plant Master Plan, Kapolei, Honolulu, Hawaii. Senior land surveyor and project manager who prepared topographic surveys for planning, engineering, and architectural services to redevelop the property.

City and County of Honolulu Board of Water Supply, Service Lateral Replacement at Mililani, Honolulu, Hawaii.

Senior land surveyor who prepared boundary and topographic surveys for the design and construction of service lateral replacements.















800.450.1818 | [email protected]
DUDEK.COM