1 Revised - RP – 09/01/2022
LAND IMPROVEMENT AGREEMENT
PM # ASP #
DR # ADDRESS #
THIS AGREEMENT made and entered into this day of , 20___, by and between the City of Fontana, hereinafter call City and hereinafter called Applicant.
WITNESSETH:
WHEREAS, it is the intention of the Applicant to improve a certain parcel or parcels of land in the City of Fontana described as
and,
WHEREAS, the City Council of the City of Fontana has approved and adopted certain rules and regulations governing the developing of land in the City and the posting of improvements securities guaranteeing the installation of necessar y permanent improvements as set forth in Article III of Chapter 25, Article IV of Chapter 26 and Article III of Chapter 27 of the Fontana City Code and,
WHEREAS, the City Code specifically sets forth the requirements for the installations of necessary improvements affecting land development.
NOW, THEREFORE, the City and the Applicant mutually agrees as follows:
The Applicant will construct or cause to be constructed at applicants expense all required permanent improvements on streets abutting his proper ty, all required tests, design work, equipment materials, and labor in order to complete all of the improvements as associated with the requirements per the approved project or to the satisfaction of the City Engineer or as specifically described and shown on approved plans on file with City Engineer and total cost estimate as stated on Exhibit “ A”, and in accordance with applicable provisions of the Standard Specifications and Standard Details of the City of Fontana in effect on the date of this Agreement.
The work shall be done under the supervision of and to the satisfaction of the City Engineer. The estimated cost of said work and improvement is the sum of ($ ) .
Surety bond for Faithful Performance in the penal sum of the estimated cost of said work and improvement shall be properly executed in favor of and delivere d to the City as part of this Agreement. In lieu of a surety bond the Applicant may deposit money or negotiable securities with the City as provided in Article III of Chapter 25, Article IV of Chapter 26 and Article III of Chapter 27 of the Fontana City Code.
The estimated cost of construction set forth in Exhibit “A” is for estimation purposes only, and for calculati on of the amount of securities required pursuant to the provisions of this section. 2 Revised - RP – 09/01/2022
Applicant’s obligation to complete the improvements, or any portion of them, is not limited in any way by the estimated cost of construction, and the obligation of Applicant’s surety in connection with the securities required pursuant to the provisions of this section.
All of the required improvements shall be completed within 12 months from the effective date of this agreement. If the work is not completed within the specified time period because of acts of God, the public enemy, the City, or because of fire, flood, epidemic, quarantine restrictions, strikes or freight embargoes, the Applicant shall be entitled to an extension beyond the specified time period for a period equal to the length of such delay within ten days from the beginning of such delay
In addition to the extension for the reasons referenced in the foregoing paragraph, Applicant may submit a written request, Exhibit “B”, for a discretionary extension of the time for completion of the improvements to the City Engineer. The City Engineer may grant or reject such extension, in whole or in part or with conditions, in his sole discretion. If an extension time is granted it shall in no way affect the validity of this contract or release the surety on the securities referenced herein.
Upon timely completion of the required improvements pursuant to the terms of this Agreement, and prior to final acceptance of the improvements by the City, Applicant shall submit to the City Engineer for review and approval, a digital copy of “ record” drawings of all improvement plans in accordance with the latest edition of the City of Fontana Electric File Submittal Requirements.
Upon the approval of “record” drawing, the City Engineer shall process the rele ase of the Applicant’s performance bond posted pursuant to the Bond Guarantee for Faithful Performance.
In the event that Applicant fails to complete the improveme nts within the required period or any approved extension, the City may complete the work and shall be entitled to recover the full cost and expenses thereof from Applicant, or his surety as herein pr ovided. If City pursues completion of the improvement work, it may require Applicant, or his surety, to pay the City in advance, sufficient monies to cover the City’s cost in completing construction of the improvements.
Any limitations period provided by law related to breach of this Agreement or the terms thereof shall not commence running until Applicant, or Applicant’s surety pursuant to this Agreement, has provided the City Engineer with written notice of Applicant’s intent to abandon or otherwise not complete the improvements.
Applicant shall defend, indemnify and hold City, its elected officials, officers, employees, and agents free and harmless from any and all liability arising out of or incident to Applicant’s performance of this Agreement, inclu ding without limitation all reasonable attorney’s fees, whether or not resulting from the negligence of Applicant or Applicant’s agents. This indemnity shall extend to any claims arising because Applicant has failed to properly secure any necessary easement, land right, contract, and approval, but shall not extend to any claim arising out of the sole negligence of City.
3 Revised - RP – 09/01/2022
It is further expressly agreed that the Applicant will procure all permits and licenses, pay all charges and fees, and give all notices necessary and incident to the due and lawful prosecution of the work.
4 Revised - RP – 09/01/2022
IN WITNESS WHEREOF, three (3) identical counterparts of this agreement, each of which shall for all purposes be deemed an original thereof, have been duly executed by the Applicant herein named on the day of , 20 the name and corporate seal of each corporate party being hereto affixed and these presents duly signed by its undersigned representative(s) pursuant to authority of its governing body.
APPLICANT CITY OF FONTANA
____________________________ By:
Signature City Engineer
Print Name
____________________________ Date:
Print Name
____________________________
Company Name
____________________________
Address
____________________________
City State Zip Code
Attachments: (1) Exhibit “A” – Cost Estimate
(2) Exhibit “B” – Time Extension
(3) Securities
11/18/2021 - RG
STAFF USE ONLY
ENGINEERING PC NO.
__________________
CITY OF FONTANA
ENGINEERING DEPARTMENT
COST ESTIMATE - EXHIBIT "A"
DATE: _____________________
DEVELOPER PROJECT NAME__________________
ENGINEER TRACT MAP NO._________________
PHONE NO. PARCEL MAP NO. _______________
STREET IMPROVEMENTS
UNIT
ITEM QUANTITY UNIT COST AMOUNT
6" CURB & GUTTER _ L.F. 17.00 __
8" CURB & GUTTER L.F. 19.00 _
8" THICK CROSS GUTTER S.F. 11.00 _
4" SIDEWALK S.F. 7.00 _
ACCESS RAMP EA 5,000.00 _
DRIVE WAY APPROACHES S.F. 11.00 _
ASPHALT CONCRETE DIKES L.F. 11.00 _
FOG SEAL S.F. .10 ____
IMPORTED EMBANKMENT C.Y. 10.00 _
PREPARATION OF SUBGRADE S.F. .50 _
*A.C. TON 150.00 _
*A.C.OVERLAY(0.20 THICKNESS)
PER CITY STANDARD TON 150.00 _
**PCC CURB ONLY (MEDIAN) L.F. 16.00 _
ADJUST SEWER MANHOLE TO GRADE EA 500.00 _
ADJUST SEWER CLEAN OUT TO
GRADE EA 300.00 _
ADJUST WATER VALVES TO GRADE EA 250.00 _
BARRICADES L.F. 40.00 _
2 X 4 REDWOOD HEADER L.F. 5.00 _
*REMOVAL OF A.C. PAVEMENT S.F. .66 _
**REMOVAL OF P.C.C. CURB L.F. 6.00 _
*REMOVAL OF A.C. BERM L.F. 5.00 _
RETAINING WALL H=2 1/2 FT.
OR LESS L.F. 40.00 ________
BLOCK WALL H=6 FEET L.F. 50.00 ________
AGGREGATE BASE TON 30.00 _ __
GUARD POSTS EA 70.00 _
GUARD PANEL (WOOD) L.F. 40.00 _
SAWCUT L.F. 3.50 _
REFLECTORS AND POSTS EA 100.00 _
STREET SIGNS EA 25 0.00 _
______________________ ________ LF _______ ________
______________________ ________ EA _______ ________ ______________________ ________ EA __ _____ ________ ______________________ ________ EA _______ ________
STREET IMPROVEMENT SUBTOTAL
* A.C. ASPHALTIC CONCRETE
** P.C.C. PORTLAND CONCRETE CEMENT
11/18/2021 - RG
STORM DRAIN IMPROVEMENTS
UNIT
ITEM QUANTITY UNIT COST AMOUNT
* 18" RCP L.F. 90.00 ________
* 24" RCP L.F. 110.00 ________
* 30" RCP L.F. 250.00 ________
* 36" RCP L.F. 250.00 ________
* 42” RCP ________ L.F. 250.00 ________
* 48" RCP L.F. 260.00 ________
* 54" RCP L.F. 280.00 ________
* 60" RCP L.F. 300.00 ________
* 66” RCP ________ L.F. 320.00 ________
* 78” RCP ________ L.F. 340.00 ________
* 24” CMP ________ L.F. 90.00 ________
* 60” CMP ________ L.F. 320.00 ________
CATCH BASIN/CURB INLET:
W=7 EA 4,000.00 ________
W=10 EA 4,500.00 ________
W=14 EA 6,000.00 ________
W=21 EA 11,000.00 ________
W=28 EA 14,000.00 ________
JUNCTION STRUCTURE EA 3,200.00 ________
TRAFFIC TYPE JUNCTION
STRUCTURE EA 2,800.00 ________
DISCHARGE STRUCTURE EA 2,800.00 ________ MANHOLES EA 2,500.00 ________
LOCAL DEPRESSION EA 1,250.00 ________
GRATE INLET STRUCTURE EA 2,100.00 ________ _____________________ ________ EA ________ ________ _____________________ ________ EA ________ ________ _____________________ ________ EA ________ ________
STORM DRAIN IMPROVEMENT SUBTOTAL ________
* REINFORCE CONCRETE PIPE
SANITARY SEWER IMPROVEMENTS
UNIT
ITEM QUANTITY UNIT COST AMOUNT
MANHOLES 60" DIAMETER EA 4,500.00 ________ MANHOLES 48" DIAMETER EA 4,000.00 ________ DROP MAN HOLES EA 4,500.00 ________
WYES EA 100.00 ________
CLEANOUTS EA 600.00 ________
REMODELING OF EXISTING
MANHOLE EA 950.00 ________
** 4" VCP L.F. 50.00 ________
** 6" VCP L.F. 60.00 ________
** 8" VCP L.F. 70.00 ________
** 10" VCP L.F. 80.00 ________
** 12" VCP L.F. 90.00 ________
** 15" VCP L.F. 100.00 ________
__________________ ________ L.F. _______ ________
__________________ ________ L.F. _______ ________
SANITARY SEWER IMPROVEMENT SUBTOTAL ________
** VITRIFIED CLAY PIPE
11/18/2021 - RG
TRAFFIC SIGNALS/SIGN/STRIPING
UNIT
ITEM QUANTITY UNIT COST AMOUNT
TRAFFIC SIGNAL MODIFICATION:
ONE CORNER L.S. 75,000.00 _
TWO CORNERS L.S. 100,000.00 _
TRAFFIC SIGNAL NEW L.S. 400,000.00 _
PAINT TRAFFIC STRIPE (1 COAT) L.F. 2.40 _
PAINT TRAFFIC STRIPE(2 COATS) L.F. .65 _
PEDESTRIAN CROSSWALK STRIPING L.F. .65 _
PAVEMENT MARKER
(NON REFLECTIVE) EA 2.50 ________
PAVEMENT MARKER (REFLECTIVE) EA 4.00 _
REFLECTORS AND POSTS EA 100.00 _
STREET SIGNS EA 250.00 _
___________________ ________ EA ________ ________
___________________ ________ EA ________ ________
TRAFFIC SIGNAL/SIGNS/STRIPING SUBTOTAL __
CFD LANDSCAPE IMPROVEMENTS (BONDING PURPOSES ONLY)
AREA LANDSCAPED S.F. $12.00 _
CENTER MEDIAN S.F. $12.00 _
LANDSCAPING IMPROVEMENTS SUBTOTAL __________
SUBTOTALS:
STREET IMPROVEMENT SUBTOTAL....................___________________ STORM DRAIN IMPROVEMENTS SUBTOTAL..............___________________ SANITARY SEWER IMPROVEMENTS SUBTOTAL...........___________________ TRAFFIC SIGNAL/SIGNS/STRIPING SUBTOTAL.........___________________ IMPROVEMENT SUBTOTAL ===================
(*USE THIS TOTAL FOR PLAN CHECK & PERMITTING PURPOSES*) CFD LANDSCAPE IMPROVEMENTS ....................___________________ SUBDIVISION MONUMENT GUARANTEE $1,200 + $50/LOT ...___________________ STREET LIGHTS _______ @ $5,000 ................___________________ CUCAMONGA COUNTY WATER DISTRICT FACILITIES.....___________________ IMPROVEMENT SUBTOTAL.... ===================
ADD 35%..................... ____________________
BONDING TOTAL........___________________
11/18/2021 - RG
APPROVED PUBLIC IMPROVEMENT PLANS:
STREET IMP. DWG. NO._____________________
STREET LIGHT DWG. NO.____________________
SEWER IMP. DWG. NO.______________________
STORM DRAIN IMP. DWG. NO. _______________
TRAFFIC SIGNAL DWG. NO.__________________
SIGNING & STRIPING DWG. NO.______________
6 Revised - RP – 09/01/2022
Bond No.
Premium $
BOND GUARANTEE FOR FAITHFUL PERFORMANCE
Land Improvement Agreement
WHEREAS, the City of Fontana, State of California, and
hereinafter designated as
“Applicant” have entered in to an agreement whereby applicant agrees to install and complete certain designated public improvements which said agreemen t, dated _____________, and identified as __________________________________________ is hereby referred to and made a part hereof; and
WHEREAS, said applicant is required under the terms of said agreement to furnish a bond for the faithful performance of said agreement.
NOW, THEREFORE, we the applicant and
as surety, are held and fir mly bound unto the City of F ontana, hereinafter called the City, in the penal sum of ($ )
lawful money of the United States, for th e payment of which sum well and truly to be made, we bind ourselves, our heirs, successors, executors and administrators, jointly and severally, firmly by those presents.
The condition of this obligation is such that if the above bonded applicant, his or its heirs, executors, administrators, successors, or assigns, shall in all things stand to and truly keep and perform the covenants, conditions and provisions in the said agreement and any alteration thereof made as therein provi ded, on his or their part, to be kept and performed at the time and in the manner therein specified, and in all respects according t o their true intent and meaning, and shall indemnify and hold harmless the City, its officers, agents and employees, as the rein stipulated, then this obligation shall become null and void; otherwise it shall be and remain in full force and effect, pursuant to Article III of Chapter 25, Article IV of Chapter 26 and Article III of Chapter 27 Fontana City Code, and any amendments thereto, for the installation of construction of:
As part of the obligation secured hereby and in addition to the fac e amount specified hereon, there shall be included costs and reasonable expenses and fees including reasonable attorney’s fees, incurred by the City in successfully enforcing such obligation all to be taxed as costs and included in any judgment rendered.
The surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the agree ment or to the work to be performed thereunder or the specifications accompanying the same shall in any w ise affect its obligations o n this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the agreement or to the work or to the specifications.
7 Revised - RP – 09/01/2022
IN WITNESS WHEREOF, this instrument has been duly executed by the applicant and surety above named, on .
(seal)
Applicant
(seal)
Surety
NOTE: Signature for those executing for the surety must be properly acknowledge.
8 Revised - RP – 09/01/2022
LAND IMPROVEMENT AGREEMENT
EXHIBIT “B”
I,
(Applicant’s name here)
am the owner of the property to which this Request is being made for a One Year Time Extension for Project No. .
Print Name:
Applicant’s Signature:
Applicant’s Address:
Date:
(Attached Notary Acknowledgment)
CITY OF FONTANA
BY: DATE:
City Engineer
[ ] DENY
[ ] APPROVED
NEW DATE: