Irwindale City Council
May 14, 2025

-6-
01005.0006 2004640.1

1.10 Warranty.

Contractor warrants all work under the Agreement (which for purposes of this Section shall be deemed to include unauthorized work which has not been removed and any non-conforming materials incorporated into the work) to be of good quality and free from any defective or faulty material and workmanship. Contractor agrees that for a period of one year (or the period of time specified elsewhere in the Agreement or in any guarantee or warranty provided by any manufacturer or supplier of equipment or materials incorporated into the work, whichever is later) after the date of final acceptance, Contractor shall within ten (10) days after being notified in writing by the City of any defect in the work or non-conformance of the work to the Agreement, commence and prosecute with due diligence all work necessary to fulfill the terms of the warranty at its sole cost and expense. Contractor shall act as soon as requested by the City in response to an emergency. In addition, Contractor shall, at its sole cost and expense, repair, remove and replace any portions of the work (or work of other contractors) damaged by its defective work or which becomes damaged in the course of repairing or replacing defective work. For any work so corrected, Contractor’s obligation hereunder to correct defective work shall be reinstated for an additional one year period, commencing with the date of acceptance of such corrected work.

Contractor shall perform such tests as the City may require to verify that any corrective actions, including, without limitation, redesign, repairs, and replacements comply with the requirements of the Agreement. All costs associated with such corrective actions and testing, including the removal, replacement, and reinstitution of equipment and materials necessary to gain access, shall be the sole responsibility of the Contractor. All warranties and guarantees of subcontractors, suppliers and manufacturers with respect to any portion of the work, whether express or implied, are deemed to be obtained by Contractor for the benefit of the City, regardless of whether or not such warranties and guarantees have been transferred or assigned to the City by separate agreement and Contractor agrees to enforce such warranties and guarantees, if necessary, on behalf of the City. In the event that Contractor fails to perform its obligations under this Section, or under any other warranty or guaranty under this Agreement, to the reasonable satisfaction of the City, the City shall have the right to correct and replace any defective or non-conforming work and any work damaged by such work or the replacement or correction thereof at Contractor’s sole expense.

Contractor shall be obligated to fully reimburse the City for any expenses incurred hereunder upon demand.

1.11 Additional Work and Change Orders.
(a) City shall have the right at any time during the performance of the services, without invalidating this Agreement, to order extra work beyond that specified in the Scope of Work or make changes by altering, adding to or deducting from said work. No such extra work may be undertaken unless a written change order is first given by the City’s Director of Public Works Engineering or City Engineer, or either of their designees, to the Contractor, incorporating therein any adjustment in (i) the Contract Sum, and/or (ii) the time to perform this Agreement, which said adjustments are subject to the written approval of the Contractor (“Change Order”).

All Change Orders must be signed by the Contractor and City’s Director of Public Works Engineering or City Engineer, or either of their designees, prior to commencing the extra work thereunder.

-7-
01005.0006 2004640.1
(b) Any increase in compensation of up to ten percent (10%) of the Contract Sum or any increase in the time to perform of up to one hundred eighty (180) working days and which are not detrimental to the Work or to the interest of the City, may be approved by the City’s Director of Public Works Engineering or City Engineer, or either of their designees. Any greater increases, taken either separately or cumulatively, must be approved by the City Council. (c) Any adjustment in the Contract Sum for a Change Order must be in accordance with the rates set forth in the Contractor’s Bid. If the rates in the Contractor’s Bid do not cover the type of work in the Change Order, the cost of such work shall not exceed an amount agreed upon in writing and signed by Contractor and City’s Director of Public Works Engineering or City Engineer, or either of their designees. If the cost of the Change Order cannot be agreed upon, the City will pay for actual work of the Change Order completed, to the satisfaction of the City, as follows:
(i) Labor: The cost of labor shall be the actual cost for wages of workers and subcontractors performing the work for the Change Order at the time such work is done. The use of labor classifications that would increase the cost of such work shall not be permitted.
(ii) Materials and Equipment: The cost of materials and equipment shall be at cost to Contractor or lowest current price which such materials and equipment are reasonably available at the time the work is done, whichever is lower. (iii) If the cost of the extra work cannot be agreed upon, the Contractor must provide a daily report that includes invoices for labor, materials and equipment costs for the work under the Change Order. The daily report must include: list of names of workers, classifications, and hours worked; description and list of quantities of materials used; type of equipment, size, identification number, and hours of operation, including loading and transportation, if applicable; description of other City authorized services and expenditures in such detail as the City may require. Failure to submit a daily report by the close of the next working day may, at the City’s sole and absolute discretion, waive the Contractor’s rights for that day. (d) It is expressly understood by Contractor that the provisions of this Section shall not apply to services specifically set forth in the Scope of Work. Contractor hereby acknowledges that it accepts the risk that the services to be provided pursuant to the Scope of Work may be more costly or time consuming than Contractor anticipates and that Contractor shall not be entitled to additional compensation therefor. City may in its sole and absolute discretion have similar work done by other contractors.
(e) No claim for an increase in the Contract Sum or time for performance shall be valid unless the procedures established in this Section are followed.

1.12 Special Requirements.

Additional terms and conditions of this Agreement, if any, which are made a part hereof are set forth in the “Special Requirements,” attached hereto as Exhibit B and incorporated herein by this reference. In the event of a conflict between the provisions of Exhibit B and any other provisions of this Agreement, the provisions of Exhibit B shall govern.

-8-
01005.0006 2004640.1
ARTICLE 2. COMPENSATION AND METHOD OF PAYMENT.

2.1 Contract Sum.

Subject to any limitations set forth in this Agreement, City agrees to pay Contractor the amounts set forth in the “Schedule of Compensation,” attached hereto as Exhibit C and incorporated herein by this reference. Subject to any additions or deductions that may be made by change order or amendment, and any penalties or damages that may be assessed against Contractor, Contractor shall receive total compensation, including reimbursement of Contractor’s expenses, of an amount not to exceed One Hundred Ninety-Six Thousand, One Hundred Eighty Dollars ($196,180.00) (“Contract Sum”) for completion of the work. The Contract Sum shall constitute full compensation for furnishing all materials and for doing all the work contemplated and embraced in this Agreement; and also for all loss or damage arising out of the nature of the work, or from any unforeseen difficulties or obstructions which may arise or be encountered in the prosecution of the work until its acceptance by the City, and for all risks of every description connected with the work; also for all expenses incurred by or in consequence of the suspension or discontinuance of work and for well and faithfully completing the work, and the whole thereof, in the manner and according to the plans and specifications, and the requirements of the Bid Documents and this Agreement. The Contract Sum shall be made in the form of progress payments subject to retention pursuant to Section 2.4.

2.2 Invoices.

Each month Contractor shall furnish to City an original invoice for all work performed during the preceding month in a form approved by City’s Director of Finance. By submitting an invoice for payment under this Agreement, Contractor is certifying compliance with all provisions of the Agreement.

All invoices shall include a copy of Contractor’s Certified Payroll and proof that Certified Payroll has been submitted to the DIR. Contractor shall also submit a list of the prevailing wage rates (including federal prevailing wage rates, if applicable) for all employees and subcontractors providing services under this Agreement, as applicable, with Contractor’s first invoice. If these rates change at any time during the term of the Agreement, Contractor shall submit a new list of rates to the City with its first invoice following the effective date of the rate change.

2.3 Payment.
(a) Payments Made by City. City shall independently review each invoice submitted by the Contractor to determine whether the work performed and expenses incurred are in compliance with the provisions of this Agreement. Except as to any charges for work performed or expenses incurred by Contractor which are disputed by City, City will cause Contractor to be paid any progress payment within thirty (30) days of receipt of Contractor’s correct and undisputed invoice; however, Contractor acknowledges and agrees that due to City warrant run procedures, the City cannot guarantee that payment will occur within this time period. In the event that City does not cause Contractor to be paid any progress payment within thirty (30) days of receipt of an undisputed and properly submitted invoice and provided the Project is for construction, Contractor shall be entitled to the payment of interest to the extent allowed under Public Contract Code

-9-
01005.0006 2004640.1
Section 20104.50. In the event any charges or expenses are disputed by City, the original invoice shall be returned by City to Contractor, not later than seven (7) days after receipt by the City, for correction and resubmission. Returned invoices shall be accompanied by a document setting forth in writing the reasons why the payment request was rejected. Review and payment by the City of any invoice provided by the Contractor shall not constitute a waiver of any rights or remedies provided herein or any applicable law.
(b) Payments Made by Contractor to Subcontractors. Contractor shall remit payments owed to subcontractors within fifteen (15) calendar days after receiving payments by City if payments are owed by Contractor to any subcontractor qualifying as a small business enterprise, and within thirty (30) calendar days if payments are owed by Contractor to any subcontractor other than a small business enterprise.

2.4 Retention.

Pursuant to Section 9203 of the Public Contract Code, City will deduct a five percent (5%) retention from all progress payments, which shall be released to Contractor no later than sixty (60) days from completion of the work in accordance with Section 7107 of the Public Contract Code.

In the event of a dispute between City and Contractor, City may withhold from the final payment an amount not to exceed one hundred fifty percent (150%) of the disputed amount.

2.5 Waiver.

Payment to Contractor for work performed pursuant to this Agreement shall not be deemed to waive any defects in work performed by Contractor.

2.6 Substitution of Securities.
(a) In conformance with the State of California Public Contract Code, Part 5, Section 22300, Contractor may substitute securities for any monies withheld by the City to ensure performance under this Agreement.
(b) At the request and expense of Contractor, Contractor has the option of establishing an escrow account with a state or federally chartered bank which shall serve as an escrow agent, for Contractor’s direct deposit of securities as a substitute for retention earnings required to be withheld by the City. Upon Contractor’s completion of its obligations hereunder, as evidenced by the City’s acceptance of the work pursuant to Section 3.3 hereof, the escrow agent shall return the securities to Contractor. The escrow agent shall notify the City within ten (10) days after deposit of the securities. The market value of the securities at the time of the substitution shall be at least equal to the cash amount then required to be withheld as retention. Securities shall be held in the name of the City and shall designate Contractor as the beneficial owner. Alternatively, on written request of Contractor, the City shall make payments of the retention earnings directly to the escrow account.

-10-
01005.0006 2004640.1
ARTICLE 3. PERFORMANCE SCHEDULE

3.1 Schedule of Performance.

Contractor shall complete the Project within Thirty (30) calendar days after receiving a “Notice to Proceed” from the City in accordance with any schedule contained in or required to be provided by the Proposal or Bid Documents, and any revisions thereof approved by the City in writing. Time is of the essence. If the work is not completed within said time period, liquidated damages shall apply. The term of this Agreement shall expire one (1) year following City’s acceptance of the Project.

3.2 Liquidated Damages.

Since the determination of actual damages for any delay in performance of this Agreement would be extremely difficult or impractical to determine in the event of a breach of this Agreement, the Contractor and its sureties shall be liable for and shall pay to the City the sum of Five Hundred Dollars ($500.00) as liquidated damages for each working day of delay in the performance of any service required hereunder. The City may withhold any accrued liquidated damages from any monies payable on account of services performed by the Contractor. To the extent required by Government Code section 4215, Contractor shall not be assessed liquidated damages for delay in completion of the work when such delay was caused by the failure of the City or owner of the utility to provide for removal or relocation of utility facilities.

3.3 Force Majeure.

The time period(s) specified in the Schedule of Performance for performance of the services rendered pursuant to this Agreement shall be extended because of any delays due to unforeseeable causes beyond the control and without the fault or negligence of the Contractor, including, but not restricted to, acts of God or of the public enemy, unusually severe weather, fires, earthquakes, floods, epidemics, quarantine restrictions, riots, strikes, freight embargoes, wars, litigation, and/or acts of any governmental agency, including the City, if the Contractor shall within ten (10) days of the commencement of such delay notify the Project Manager in writing of the causes of the delay. The Project Manager shall ascertain the facts and the extent of delay, and extend the time for performing the services for the period of the enforced delay when and if in the judgment of the Project Manager such delay is justified. The Project Manager’s determination shall be final and conclusive upon the Parties to this Agreement. In no event shall Contractor be entitled to recover damages against the City for any delay in the performance of this Agreement, however caused, Contractor’s sole remedy being extension of the Agreement pursuant to this Section.

3.4 Final Acceptance.

Acceptance of the Project shall only be by action of the City Council. Neither the acceptance nor any prior inspections or failure to inspect shall constitute a waiver by City of any defects in the work. From and after acceptance, the Project shall be owned and operated by City.

As a condition to acceptance, Contractor shall certify to City in writing that all of the work has been performed in strict conformity with the Agreement and that all costs have been paid or supplied to City for security required herein, satisfactory to City, guaranteeing such performance.

-11-
01005.0006 2004640.1
ARTICLE 4. COORDINATION OF WORK

4.1 Representatives and Personnel of Contractor.

The following principals of Contractor (“Principals”) are hereby designated as being the principals and representatives of Contractor authorized to act on its behalf with respect to the work specified herein and make all decisions in connection therewith:

Noam Ziv _ President/CEO .
(Name) (Title)
________________________ ________________________
(Name) (Title)
The Principals shall be responsible during the term of this Agreement for directing all activities of Contractor and devoting sufficient time to personally supervise the services hereunder. All personnel of Contractor, and any authorized agents, shall at all times be under the exclusive direction and control of the Principals. For purposes of this Agreement, the Principals may not be replaced nor may their responsibilities be substantially reduced by Contractor without the express written approval of City. Additionally, Contractor shall make every reasonable effort to maintain the stability and continuity of Contractor’s staff and subcontractors, if any, assigned to perform the services required under this Agreement. Contractor shall notify City of any changes in Contractor’s staff and subcontractors, if any, assigned to perform the services required under this Agreement, prior to and during any such performance.

4.2 Status of Contractor.

Contractor shall have no authority to bind City in any manner, or to incur any obligation, debt or liability of any kind on behalf of or against City, whether by contract or otherwise, unless such authority is expressly conferred under this Agreement or is otherwise expressly conferred in writing by City. Contractor shall not at any time or in any manner represent that Contractor or any of Contractor’s officers, employees, or agents are in any manner officials, officers, employees or agents of City. Neither Contractor, nor any of Contractor’s officers, employees or agents, shall obtain any rights to retirement, health care or any other benefits which may otherwise accrue to City’s employees. Contractor expressly waives any claim Contractor may have to any such rights.

4.3 Project Manager.

The Project Manager shall be Eddie Chan or any other person as may be designated by the City’s Director of Public Works Engineering or City Engineer. It shall be the Contractor’s responsibility to assure that the Project Manager is kept informed of the progress of the performance of the services and the Contractor shall refer any decisions which must be made by City to the Project Manager. Unless otherwise specified herein, any approval of City required hereunder shall mean the approval of the Project Manager. The Project Manager shall have authority, if specified in writing by the City’s Director of Public Works Engineering or City

-12-
01005.0006 2004640.1
Engineer, to sign all documents on behalf of the City required hereunder to carry out the terms of this Agreement.

4.4 Independent Contractor.

Neither the City nor any of its employees shall have any control over the manner, mode or means by which Contractor, its agents or employees, perform the services required herein, except as otherwise set forth herein. City shall have no voice in the selection, discharge, supervision or control of Contractor’s employees, servants, representatives or agents, or in fixing their number, compensation or hours of service. Contractor shall perform all services required herein as an independent contractor of City and shall remain at all times as to City a wholly independent contractor with only such obligations as are consistent with that role. City shall not in any way or for any purpose become or be deemed to be a partner of Contractor in its business or otherwise or a joint venturer or a member of any joint enterprise with Contractor.

4.5 Prohibition Against Subcontracting or Assignment.

The experience, knowledge, capability and reputation of Contractor, its principals and employees were a substantial inducement for the City to enter into this Agreement. Therefore, Contractor shall not contract with any other entity to perform in whole or in part the services required hereunder without the express written approval of the City. All subcontractors shall obtain, at its or Contractor’s expense, such licenses, permits, registrations and approvals (including from the City) as may be required by law for the performance of any services or work under this Agreement. In addition, neither this Agreement nor any interest herein may be transferred, assigned, conveyed, hypothecated or encumbered voluntarily or by operation of law, whether for the benefit of creditors or otherwise, without the prior written approval of City. Transfers restricted hereunder shall include the transfer to any person or group of persons acting in concert of more than twenty five percent (25%) of the present ownership and/or control of Contractor, taking all transfers into account on a cumulative basis. In the event of any such unapproved transfer, including any bankruptcy proceeding, this Agreement shall be void. No approved transfer shall release the Contractor or any surety of Contractor of any liability hereunder without the express consent of City.

ARTICLE 5. INSURANCE, INDEMNIFICATION AND BONDS

5.1 Insurance Coverages.

Without limiting Contractor’s indemnification of City, and prior to commencement of any services under this Agreement, Contractor shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City.
(a) General liability insurance. Contractor shall maintain commercial general liability insurance with coverage at least as broad as Insurance Services Office form CG 00 01, in an amount not less than $1,000,000 per occurrence, $2,000,000 general aggregate, for bodily injury, personal injury, and property damage. The policy must include contractual liability that has not been amended. Any endorsement restricting standard ISO “insured contract” language will not be accepted.

-13-
01005.0006 2004640.1
(b) Automobile liability insurance. Contractor shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of the Contractor arising out of or in connection with Services to be performed under this Agreement, including coverage for any owned, hired, non-owned or rented vehicles, in an amount not less than $2,000,000 combined single limit for each accident. (c) Workers’ compensation insurance. Contractor shall maintain Workers’ Compensation Insurance (Statutory Limits) and Employer’s Liability Insurance (with limits of at least $1,000,000).
(d) Builder’s Risk Insurance. Contractor shall maintain Builder’s Risk (Course of Construction) insurance utilizing an “All Risk” (Special Perils) coverage form, with limits equal to the completed value of the project and no coinsurance penalty provisions or provisional limit provisions. The policy must include: (1) coverage for any ensuing loss from faulty workmanship, nonconforming work, omission or deficiency in design or specifications; (2) coverage against machinery accidents and operational testing; (3) coverage for removal of debris, and insuring the buildings, structures, machinery, equipment, materials, facilities, fixtures and all other properties constituting a part of the project; (4) ordinance or law coverage for contingent rebuilding, demolition, and increased costs of construction; (5) transit coverage (unless insured by the supplier or receiving contractor), with sub-limits sufficient to insure the full replacement value of any key equipment item; (6) ocean marine cargo coverage insuring any project materials or supplies, if applicable; (7) coverage with sub-limits sufficient to insure the full replacement value of any property or equipment stored either on or off the project site or any staging area.

If the Project does not involve new or major reconstruction, then at the option of City, an Installation Floater may be acceptable. For such projects, a Property Installation Floater shall be obtained that provides for the improvement, remodel, modification, alteration, conversion or adjustment to existing buildings, structures, processes, machinery and equipment. The Property Installation Floater shall provide property damage coverage for any building, structure, machinery or equipment damaged, impaired, broken, or destroyed during the performance of the work, including during transit, installation, and testing at the Project site.
(e) Pollution Liability Insurance. Contractor shall maintain Environmental Impairment Liability insurance, written on a Contractor’s Pollution Liability form or other form acceptable to City providing coverage for liability arising out of sudden, accidental, and gradual pollution and remediation. The policy limit shall be no less than $1,000,000 per claim and in the aggregate. All activities contemplated in this Agreement shall be specifically scheduled on the policy as “covered operations.” The policy shall provide coverage for the hauling of waste from the project site to the final disposal location, including non-owned disposal sites.

Products/completed operations coverage shall extend a minimum of three (3) years after project completion. Coverage shall be included on behalf of the insured for covered claims arising out of the actions of independent contractors. If the insured is using subcontractors, the policy must include work performed “by or on behalf” of the insured. Policy shall contain no language that would invalidate or remove the insurer’s duty to defend or indemnify for claims or suits expressly excluded from coverage. Policy shall specifically provide for a duty to defend on the part of the insurer.

-14-
01005.0006 2004640.1
If Contractor maintains broader coverage and/or higher limits than the minimums shown above, City requires and shall be entitled to the broader coverage and/or the higher limits maintained by Contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to City.

5.2 General Insurance Requirements.
(a) Subcontractors. Contractor shall include all subcontractors as insureds under its policies or shall furnish separate certificates and certified endorsements for each subcontractor. All coverages for subcontractors shall include all of the requirements stated herein. (b) Proof of Insurance. Contractor shall provide certificates of insurance and endorsements to City as evidence of the insurance coverages required herein, along with a waiver of subrogation endorsement for workers’ compensation. Insurance certificates and endorsements must be approved by City’s Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. City reserves the right to require complete, certified copies of all required insurance policies, at any time.
(c) Duration of Coverage. Contractor shall procure and maintain for the duration of this Agreement insurance against claims for injuries to persons or damages to property, which may arise from or in connection with the performance of the Services hereunder by Contractor, its agents, representatives, employees or subcontractors. (d) Primary/noncontributing. Coverage provided by Contractor shall be primary and any insurance or self-insurance procured or maintained by City shall not be required to contribute with it. The limits of insurance required herein may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and noncontributory basis for the benefit of City before the City’s own insurance or self-insurance shall be called upon to protect it as a named insured.
(e) City’s Rights of Enforcement. In the event any policy of insurance required under this Agreement does not comply with these specifications or is canceled and not replaced, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Contractor or City will withhold amounts sufficient to pay premium from Contractor payments. In the alternative, City may cancel this Agreement. (f) Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this agreement shall be endorsed to waive subrogation against City, its elected or appointed officers, agents, officials, employees and volunteers or shall specifically allow Contractor or others providing insurance evidence in compliance with these specifications to waive their right of recovery prior to a loss. Contractor hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subcontractors.
(g) Enforcement of Contract Provisions (non-estoppel). Contractor acknowledges and agrees that any actual or alleged failure on the part of the City to inform

-15-
01005.0006 2004640.1
Contractor of non-compliance with any requirement imposes no additional obligations on the City nor does it waive any rights hereunder.
(h) Requirements Not Limiting. Requirements of specific coverage features or limits contained in this section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. If the Contractor maintains higher limits than the minimums shown above, the City requires and shall be entitled to coverage for the higher limits maintained by the Contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City.
(i) Notice of Cancellation. Contractor agrees to oblige its insurance agent or broker and insurers to provide to City with a thirty (30) day notice of cancellation (except for nonpayment for which a ten (10) day notice is required) or nonrenewal of coverage for each required coverage.
(j) Additional Insured Status. General and auto liability policies shall provide or be endorsed to provide that City and its officers, officials, employees, and agents, and volunteers shall be additional insureds under such policies. This provision shall also apply to any excess/umbrella liability policies.
(k) Prohibition of Undisclosed Coverage Limitations. None of the coverages required herein will be in compliance with these requirements if they include any limiting endorsement of any kind that has not been first submitted to City and approved of in writing. (l) Separation of Insureds. A severability of interests provision must apply for all additional insureds ensuring that Contractor’s insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the insurer’s limits of liability. The policy(ies) shall not contain any cross-liability exclusions. (m) Pass Through Clause. Contractor agrees to ensure that its subconsultants, subcontractors, and any other party involved with the project who is brought onto or involved in the project by Contractor, provide the same minimum insurance coverage and endorsements required of Contractor. Contractor agrees to monitor and review all such coverage and assumes all responsibility for ensuring that such coverage is provided in conformity with the requirements of this section. Contractor agrees that upon request, all agreements with consultants, subcontractors, and others engaged in the project will be submitted to City for review. (n) Agency’s Right to Revise Specifications. The City reserves the right at any time during the term of the contract to change the amounts and types of insurance required by giving the Contractor ninety (90) days advance written notice of such change. If such change results in substantial additional cost to the Contractor, the City and Contractor may renegotiate Contractor’s compensation.
(o) Self-Insured Retentions. Any self-insured retentions must be declared to and approved by City. City reserves the right to require that self-insured retentions be eliminated,

-16-
01005.0006 2004640.1
lowered, or replaced by a deductible. Self-insurance will not be considered to comply with these specifications unless approved by City.
(p) Timely Notice of Claims. Contractor shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Contractor’s performance under this Agreement, and that involve or may involve coverage under any of the required liability policies.
(q) Additional Insurance. Contractor shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the work.

5.3 Indemnification.

Contractor shall indemnify, defend with legal counsel approved by City, and hold harmless City, its officers, officials, employees and volunteers (each, an “Indemnitee”) from and against all liability, loss, damage, expense, cost (including without limitation reasonable legal counsel fees, expert fees and all other costs and fees of litigation) of every nature arising out of or in connection with Contractor's performance of work under this Agreement or its failure to comply with any of its obligations contained in this Agreement, except such loss or damage which is caused by the sole or active negligence or willful misconduct of the City. Should conflict of interest principles preclude a single legal counsel from representing both City and Contractor, or should City otherwise find Contractor’s legal counsel unacceptable, then Contractor shall reimburse the City its costs of defense, including without limitation reasonable legal counsels fees, expert fees and all other costs and fees of litigation. The Contractor shall promptly pay any final judgment rendered against the City (and its officers, officials, employees and volunteers) with respect to claims determined by a trier of fact to have been the result of the Contractor’s negligent, reckless or wrongful performance. It is expressly understood and agreed that the foregoing provisions are intended to be as broad and inclusive as is permitted by the law of the State of California and will survive termination of this Agreement.

Contractor obligations under this section apply regardless of whether or not such claim, charge, damage, demand, action, proceeding, loss, stop notice, cost, expense, judgment, civil fine or penalty, or liability was caused in part or contributed to by an Indemnitee. However, without affecting the rights of City under any provision of this Agreement, Contractor shall not be required to indemnify and hold harmless City for liability attributable to the active negligence of City, provided such active negligence is determined by agreement between the parties or by the findings of a court of competent jurisdiction. In instances where City is shown to have been actively negligent and where City’s active negligence accounts for only a percentage of the liability involved, the obligation of Contractor will be for that entire portion or percentage of liability not attributable to the active negligence of City.

5.4 Notification of Third-Party Claims.

City shall timely notify Contractor of the receipt of any third-party claim relating to the work under this Agreement. City shall be entitled to recover from Contractor its reasonable costs incurred in providing such notification.

-17-
01005.0006 2004640.1

5.5 Performance and Payment Bonds.

Concurrently with execution of this Agreement, Contractor shall deliver to the City all of the following bonds if the Contract Sum should exceed $25,000:
(a) A performance bond securing the faithful performance of this Agreement, in an amount not less than 100% of the total compensation for this Agreement, as stated in Section

2.1. (b) A payment bond, securing the payment of all persons furnishing labor and/or materials in connection with the work under this Agreement, in an amount not less than 100% of the total compensation for this Agreement, as stated in Section 2.1.

All bonds shall be on the applicable forms provided in Exhibit “D” and Exhibit “E” attached hereto and made part hereof. The bonds shall each contain the original notarized signature of an authorized officer of the surety and affixed thereto shall be a certified and current copy of his/her power of attorney. The bonds shall be unconditional and remain in force during the entire term of the Agreement until released pursuant to Section 5.7 hereof.

5.6 Sufficiency of Insurer or Surety.

Insurance and bonds required by this Agreement shall be satisfactory only if issued by companies qualified to do business in California, rated “A” or better in the most recent edition of Best’s Rating Guide, The Key Rating Guide or in the Federal Register, and only if they are of a financial category Class VII or better. If the City determines that the work to be performed under this Agreement creates an increased or decreased risk of loss to the City, the Contractor agrees that the minimum limits of the insurance policies and the bonds may be changed accordingly upon receipt of written notice from the City’s Risk Manager.

5.7 Release of Securities.

City shall release the performance bond and payment bond when the following have occurred:
(a) Contractor has made a written request for release and provided evidence of satisfaction of all other requirements under Article 5 of this Agreement; (b) the Project has been accepted; and
(c) after passage of the time within which lien claims are required to be made pursuant to applicable laws; if lien claims have been timely filed, City shall hold the payment bond until such claims have been resolved, Contractor has provided statutory bond, or otherwise as required by applicable law.

-18-
01005.0006 2004640.1
ARTICLE 6. RECORDS, REPORTS, AND RELEASE OF INFORMATION

6.1 Records.

Contractor shall keep, and require subcontractors to keep, such ledgers, books of accounts, invoices, vouchers, canceled checks, reports, studies, certified and accurate copies of payroll records in compliance with all applicable laws, or other documents relating to the disbursements charged to City and services performed hereunder (the “books and records”), as shall be necessary to perform the services required by this Agreement and enable the Project Manager to evaluate the performance of such services. Any and all such documents shall be maintained in accordance with generally accepted accounting principles and shall be complete and detailed. The Project Manager shall have full and free access to such books and records at all times during normal business hours of City, including the right to inspect, copy, audit and make records and transcripts from such records. Such records shall be maintained for a period of 3 years following completion of the services hereunder, and the City shall have access to such records in the event any audit is required.

In the event of dissolution of Contractor’s business, custody of the books and records may be given to City, and access shall be provided by Contractor’s successor in interest. Notwithstanding the above, the Contractor shall fully cooperate with the City in providing access to the books and records if a public records request is made and disclosure is required by law including but not limited to the California Public Records Act.

6.2 Reports.

Contractor shall periodically prepare and submit to the Project Manager such reports concerning the performance of the services required by this Agreement as the Project Manager shall require. Contractor hereby acknowledges that the City is greatly concerned about the cost of work and services to be performed pursuant to this Agreement. For this reason, Contractor agrees that if Contractor becomes aware of any facts, circumstances, techniques, or events that may or will materially increase or decrease the cost of the work or services contemplated herein, Contractor shall promptly notify the Project Manager of said fact, circumstance, technique or event and the estimated increased or decreased cost related thereto.

6.3 Ownership of Documents.

All drawings, specifications, maps, designs, photographs, studies, surveys, data, notes, computer files, reports, records, documents and other materials (the “documents and materials”) prepared by Contractor, its employees, subcontractors and agents in the performance of this Agreement shall be the property of City and shall be delivered to City upon request of the Project Manager or upon the termination of this Agreement, and Contractor shall have no claim for further employment or additional compensation as a result of the exercise by City of its full rights of ownership use, reuse, or assignment of the documents and materials hereunder. Any use, reuse or assignment of such completed documents for other projects and/or use of uncompleted documents without specific written authorization by the Contractor will be at the City’s sole risk and without liability to Contractor, and Contractor’s guarantee and warranties shall not extend to such use, reuse or assignment. Contractor may retain copies of such documents for its own use. Contractor shall have an unrestricted right to use the concepts embodied therein. All subcontractors shall provide for assignment to City of any documents or materials prepared by them, and in the event

-19-
01005.0006 2004640.1
Contractor fails to secure such assignment, Contractor shall indemnify City for all damages resulting therefrom. Moreover, Contractor with respect to any documents and materials that may qualify as “works made for hire” as defined in 17 U.S.C. § 101, such documents and materials are hereby deemed “works made for hire” for the City.

6.4 Confidentiality and Release of Information.
(a) Information gained or work product produced by Contractor in performance of this Agreement shall be considered confidential, unless such information is in the public domain or already known to Contractor. Contractor shall not release or disclose any such information or work product to persons or entities other than City without prior written authorization from the Project Manager.
(b) Contractor, its officers, employees, agents or subcontractors, shall not, without prior written authorization from the Project Manager or unless requested by the City Attorney, voluntarily provide documents, declarations, letters of support, testimony at depositions, response to interrogatories or other information concerning the work performed under this Agreement. Response to a subpoena or court order shall not be considered “voluntary” provided Contractor gives City notice of such court order or subpoena. (c) If Contractor, or any officer, employee, agent or subcontractor of Contractor, provides any information or work product in violation of this Agreement, then City shall have the right to reimbursement and indemnity from Contractor for any damages, costs and fees, including attorneys’ fees, caused by or incurred as a result of Contractor’s conduct. (d) Contractor shall promptly notify City should Contractor, its officers, employees, agents or subcontractors be served with any summons, complaint, subpoena, notice of deposition, request for documents, interrogatories, request for admissions or other discovery request, court order or subpoena from any party regarding this Agreement and the work performed there under. City retains the right, but has no obligation, to represent Contractor or be present at any deposition, hearing or similar proceeding. Contractor agrees to cooperate fully with City and to provide City with the opportunity to review any response to discovery requests provided by Contractor. However, this right to review any such response does not imply or mean the right by City to control, direct, or rewrite said response.

ARTICLE 7. ENFORCEMENT OF AGREEMENT; DEFAULT, SUSPENSION AND

TERMINATION

7.1 California Law.

This Agreement shall be interpreted, construed and governed both as to validity and to performance of the parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim or matter arising out of or in relation to this Agreement shall be instituted in the Superior Court of the County of Los Angeles, State of California, or any other appropriate court in such county, and Contractor covenants and agrees to submit to the personal jurisdiction of such court in the event of such action. In the event of litigation in a U.S. District Court, venue shall lie exclusively in the Eastern District of California, in the County of Los Angeles, State of California.

-20-
01005.0006 2004640.1

7.2 Default of Contractor.

Contractor’s failure to comply with the provisions of this Agreement shall constitute a default. In the event that Contractor is in default for cause under the terms of this Agreement, City shall have no obligation or duty to continue compensating Contractor for any work performed after the date of default and can terminate or suspend this Agreement immediately by written notice to Contractor. If the Project Manager determines that Contractor is in default in the performance of any of the terms or conditions of this Agreement, the Project Manager shall cause to be served upon Contractor a written notice of the default. Contractor shall have ten (10) days after service upon it of said notice in which to cure the default by rendering a satisfactory performance. In the event that Contractor fails to cure its default within such period of time, the City shall have the right, notwithstanding any other provision of this Agreement, to terminate this Agreement without further notice and without prejudice to any other remedy to which it may be entitled at law, in equity or under this Agreement.

7.3 Suspension and Termination.
(a) The City may at any time, for any reason, with or without cause, suspend this Agreement, or any portion hereof, by serving upon Contractor at least ten (10) days prior written notice. Upon receipt of said notice, Contractor shall immediately cease all work under this Agreement, unless the notice provides otherwise. If the City suspends a portion of this Agreement such suspension shall not make void or invalidate the remainder of this Agreement. (b) This Agreement may be terminated by either party for cause. The City may terminate this Agreement without cause upon thirty (30) days’ written notice of termination. Upon termination, Contractor shall be entitled to compensation for completion of any portion of the Project accepted by City up to the effective date of termination unless any portion of the Project is accepted by City after termination in which event Contractor shall be paid for such completed portion.

7.4 Dispute Resolution Process.

Section 20104 et seq. of the California Public Contract Code prescribes a process utilizing informal conferences, non-binding judicial-supervised mediation, and judicial arbitration to resolve disputes on construction claims of $375,000 or less. Section 9204 of the Public Contract Code prescribes a process for negotiation and mediation to resolve disputes on construction claims.

The intent of this Section is to implement Sections 20104 et seq. and Section 9204 of the California Public Contract Code. This Section shall be construed to be consistent with said statutes.

For purposes of these procedures, “claim” means a separate demand by the Contractor, after the City has denied Contractor’s timely and duly made request for payment for extra work and/or a time extension, for (A) a time extension, (B) payment of money or damages arising from work done by or on behalf of the Contractor pursuant to the Agreement and payment of which is not otherwise expressly provided for or the Contractor is not otherwise entitled to, or (C) an amount the payment of which is disputed by the City.

The following requirements apply to all claims to which this section applies:

-21-
01005.0006 2004640.1
(a) Claim Submittal. The claim shall be in writing and include the documents necessary to substantiate the claim. Claims governed by this procedure must be filed on or before the date of final payment. Nothing in this section is intended to extend the time limit or supersede notice requirements otherwise provided in the Agreement for the filing of claims, including all requirements pertaining to compensation or payment for extra work, disputed work, and/or changed conditions. Failure to follow such contractual requirements shall bar any claims or subsequent lawsuits for compensation or payment thereon. (b) Supporting Documentation. The Contractor shall submit all claims in the following format:
(i) Summary of the claim, including references to the specific Contract Document provisions upon which the claim is based.
(ii) List of documents relating to claim: (a) Specifications, (b) Drawings, (c) Clarifications (Requests for Information), (d) Schedules, and (e) Other. (iii) Chronology of events and correspondence related to the claim. (iv) Statement of grounds for the claim.
(v) Analysis of the claim’s cost, if any.
(vi) Analysis of the claim’s time/schedule impact, if any. (c) City’s Response. Upon receipt of a claim pursuant to this section, City shall conduct a reasonable review of the claim and, within a period not to exceed 45 days, shall provide the Contractor a written statement identifying what portion of the claim is disputed and what portion is undisputed. Any payment due on an undisputed portion of the claim will be processed and made within 60 days after the City issues its written statement. (i) If the City needs approval from the City Council to provide the Contractor a written statement identifying the disputed portion and the undisputed portion of the claim, and the City Council does not meet within the 45 days or within the mutually agreed to extension of time following receipt of a claim sent by registered mail or certified mail, return receipt requested, the City shall have up to three days following the next duly publicly noticed meeting of the City Council after the 45-day period, or extension, expires to provide the Contractor a written statement identifying the disputed portion and the undisputed portion. (ii) Within 30 days of receipt of a claim, the City may request in writing additional documentation supporting the claim or relating to defenses or claims the City may have against the Contractor. If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement of City and the Contractor. (iii) The City’s written response to the claim, as further documented, shall be submitted to the Contractor within 30 days (if the claim is less than $50,000, within 15 days) after receipt of the further documentation, or within a period of time no greater than that

-22-
01005.0006 2004640.1
taken by the Contractor in producing the additional information or requested documentation, whichever is greater.
(d) Meet and Confer. If the Contractor disputes the City’s written response, or the City fails to respond within the time prescribed, the Contractor may so notify the City, in writing, either within 15 days of receipt of the City’s response or within 15 days of the City’s failure to respond within the time prescribed, respectively, and demand an informal conference to meet and confer for settlement of the issues in dispute. Upon receipt of a demand, the City shall schedule a meet and confer conference within 30 days for settlement of the dispute. (e) Mediation. Within 10 business days following the conclusion of the meet and confer conference, if the claim or any portion of the claim remains in dispute, the City shall provide the Contractor a written statement identifying the portion of the claim that remains in dispute and the portion that is undisputed. Any payment due on an undisputed portion of the claim shall be processed and made within 60 days after the City issues its written statement. Any disputed portion of the claim, as identified by the contractor in writing, shall be submitted to nonbinding mediation, with the City and the Contractor sharing the associated costs equally. The City and Contractor shall mutually agree to a mediator within 10 business days after the disputed portion of the claim has been identified in writing, unless the parties agree to select a mediator at a later time. (i) If the parties cannot agree upon a mediator, each party shall select a mediator and those mediators shall select a qualified neutral third party to mediate with regard to the disputed portion of the claim. Each party shall bear the fees and costs charged by its respective mediator in connection with the selection of the neutral mediator. (ii) For purposes of this section, mediation includes any nonbinding process, including, but not limited to, neutral evaluation or a dispute review board, in which an independent third party or board assists the parties in dispute resolution through negotiation or by issuance of an evaluation. Any mediation utilized shall conform to the timeframes in this section. (iii) Unless otherwise agreed to by the City and the contractor in writing, the mediation conducted pursuant to this section shall excuse any further obligation under Public Contract Code Section 20104.4 to mediate after litigation has been commenced. (iv) All unresolved claims shall be considered jointly in a single mediation, unless a new unrelated claim arises after mediation is completed. (f) City’s Responses. The City’s failure to respond to a claim from the Contractor within the time periods described in this section or to otherwise meet the time requirements of this section shall result in the claim being deemed rejected in its entirety. A claim that is denied by reason of the City’s failure to have responded to a claim, or its failure to otherwise meet the time requirements of this section, shall not constitute an adverse finding with regard to the merits of the claim or the responsibility of qualifications of the Contractor. City’s failure to respond shall not waive City’s rights to any subsequent procedures for the resolution of disputed claims.
(g) Government Code Claims. If following the mediation, the claim or any portion remains in dispute, the Contractor must comply with the claim procedures set forth in

-23-
01005.0006 2004640.1
Government Code Section 900 et seq. prior to filing any lawsuit against the City. Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to extra work, disputed work, construction claims, and/or changed conditions, including any required mediation, have been followed by Contractor. If no such Government Code claim is submitted, or if the prerequisite contractual requirements are not satisfied, no action against the City may be filed. A Government Code claim must be filed no earlier than the date that Contractor completes all contractual prerequisites to filing a Government Code claim, including any required mediation.

A Government Code claim shall be inclusive of all unresolved claims unless a new unrelated claim arises after the Government Code claim is submitted. For purposes of Government Code Section 900 et seq., the running of the period of time within which a claim must be filed shall be tolled from the time the Contractor submits his or her written claim to the City until the time the claim is denied, including any period of time utilized by the meet and confer conference or mediation that does not result in a complete resolutions of all claims. (h) Civil Actions for Claims of $375,000 or Less. The following procedures are established for all civil actions filed to resolve claims totaling $375,000 or less:
(i) Within 60 days, but no earlier than 30 days, following the filing or responsive pleadings, the court shall submit the matter to non-binding mediation unless waived by mutual stipulation of both parties or unless mediation was held prior to commencement of the action in accordance with Public Contract Code section 9204 and the procedures in this Section.

The mediation process shall provide for the selection within 15 days by both parties of a disinterested third person as mediator, shall be commenced within 30 days of the submittal, and shall be concluded within 15 days from the commencement of the mediation unless a time requirement is extended upon a good cause showing to the court or by stipulation of both parties.

If the parties fail to select a mediator within the 15-day period, either party may petition the court to appoint the mediator.
(ii) If the matter remains in dispute, the case shall be submitted to judicial arbitration pursuant to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, notwithstanding Section 1141.11 of that code. The Civil Discovery Act (Title 4 (commencing with Section 2016.010) of Part 4 of the Code of Civil Procedure) shall apply to any proceeding brought under this subdivision consistent with the rules pertaining to judicial arbitration.
(iii) Upon stipulation of the parties, arbitrators appointed for these purposes shall be experienced in construction law, and, upon stipulation of the parties, mediators and arbitrators shall be paid necessary and reasonable hourly rates of pay not to exceed their customary rate, and such fees and expenses shall be paid equally by the parties, except in the case of arbitration where the arbitrator, for good cause, determines a different division. (iv) In addition to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, any party who after receiving an arbitration award requests a trial de novo but does not obtain a more favorable judgment shall, in addition to payment of costs and fees under that chapter, pay the attorney's fees of the other party arising out of the trial de novo.

-24-
01005.0006 2004640.1

7.5 Waiver.

Waiver by any party to this Agreement of any term, condition, or covenant of this Agreement shall not constitute a waiver of any other term, condition, or covenant. Waiver by any party of any breach of the provisions of this Agreement shall not constitute a waiver of any other provision or a waiver of any subsequent breach or violation of any provision of this Agreement.

Acceptance by City of any work or services by Contractor shall not constitute a waiver of any of the provisions of this Agreement. No delay or omission in the exercise of any right or remedy by a non-defaulting party on any default shall impair such right or remedy or be construed as a waiver.

Any waiver by either party of any default must be in writing and shall not be a waiver of any other default concerning the same or any other provision of this Agreement.

7.6 Rights and Remedies Are Cumulative.

Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative and the exercise by either party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other party.

7.7 Unfair Business Practices Claims.

Pursuant to Public Contract Code section 7103.5, in entering into this Agreement, Contractor offers and agrees to assign to the City all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. § 15) or under the Cartwright Act (Chapter 2, (commencing with Section 16700) of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services or materials related to this Agreement. This assignment shall be made and become effective at the time the City tenders final payment to the Contractor without further acknowledgment by the Parties.

ARTICLE 8. CITY OFFICERS AND EMPLOYEES: NON-DISCRIMINATION

8.1 Non-liability of City Officers and Employees.

No officer or employee of the City shall be personally liable to the Contractor, or any successor in interest, in the event of any default or breach by the City or for any amount which may become due to the Contractor or to its successor, or for breach of any obligation of the terms of this Agreement.

8.2 Conflict of Interest.

Contractor covenants that neither it, nor any officer or principal of its firm, has or shall acquire any interest, directly or indirectly, which would conflict in any manner with the interests of City or which would in any way hinder Contractor’s performance of services under this Agreement. Contractor further covenants that in the performance of this Agreement, no person having any such interest shall be employed by it as an officer, employee, agent or subcontractor without the express written consent of the Project Manager. Contractor agrees to at all times avoid

-25-
01005.0006 2004640.1
conflicts of interest or the appearance of any conflicts of interest with the interests of City in the performance of this Agreement.

No officer or employee of the City shall have any financial interest, direct or indirect, in this Agreement nor shall any such officer or employee participate in any decision relating to the Agreement which affects his financial interest or the financial interest of any corporation, partnership or association in which he is, directly or indirectly, interested, in violation of any State statute or regulation. The Contractor warrants that it has not paid or given and will not pay or give any third party any money or other consideration for obtaining this Agreement.

8.3 Covenant Against Discrimination.

Contractor covenants that, by and for itself, its heirs, executors, assigns, and all persons claiming under or through them, there shall be no discrimination against or segregation of, any person or group of persons on account of race, color, creed, religion, sex, gender, sexual orientation, marital status, national origin, ancestry, or other protected class in the performance of this Agreement. Contractor shall take affirmative action to insure that applicants are employed and that employees are treated during employment without regard to their race, color, creed, religion, sex, gender, sexual orientation, marital status, national origin, ancestry, or other protected class.

8.4 Unauthorized Aliens.

Contractor hereby promises and agrees to comply with all of the provisions of the Federal Immigration and Nationality Act, 8 U.S.C. § 1101 et seq., as amended, and in connection therewith, shall not employ unauthorized aliens as defined therein. Should Contractor so employ such unauthorized aliens for the performance of work and/or services covered by this Agreement, and should any liability or sanctions be imposed against City for such use of unauthorized aliens, Contractor hereby agrees to and shall reimburse City for the cost of all such liabilities or sanctions imposed, together with any and all costs, including attorneys’ fees, incurred by City.

ARTICLE 9. MISCELLANEOUS PROVISIONS

9.1 Provisions Required By Law.

Each and every provision of law and clause required by law to be inserted in this Agreement shall be deemed to be inserted herein, and the Agreement shall be read and enforced as though it were included herein. If through mistake or otherwise any such provision is not inserted, or is not correctly inserted, then upon application of either party, the contract shall forthwith be physically amended to make such insertion or correction.

9.2 Notices.

Any notice, demand, request, document, consent, approval, or communication either party desires or is required to give to the other party or any other person shall be in writing and either served personally or sent by prepaid, first-class mail, in the case of the City, to the City Manager and to the attention of the Project Manager (with her/his name and City title), City of Irwindale, 5050 N. Irwindale Ave, Irwindale, California 91706 and in the case of the Contractor, to the person(s) at the address designated on the execution page of this Agreement. Either party may

-26-
01005.0006 2004640.1
change its address by notifying the other party of the change of address in writing. Notice shall be deemed communicated at the time personally delivered or in seventy-two (72) hours from the time of mailing if mailed as provided in this Section.

9.3 Interpretation.

The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of this Agreement or any other rule of construction which might otherwise apply.

9.4 Counterparts.

This Agreement may be executed in counterparts, each of which shall be deemed to be an original, and such counterparts shall constitute one and the same instrument.

9.5 Integration; Amendment.

This Agreement including the attachments hereto is the entire, complete and exclusive expression of the understanding of the parties. It is understood that there are no oral agreements between the parties hereto affecting this Agreement and this Agreement supersedes and cancels any and all previous negotiations, arrangements, agreements and understandings, if any, between the parties, and none shall be used to interpret this Agreement. No amendment to or modification of this Agreement shall be valid unless made in writing and approved by the Contractor and by the City Council. The parties agree that this requirement for written modifications cannot be waived and that any attempted waiver shall be void.

9.6 Severability.

In the event that any one or more of the phrases, sentences, clauses, paragraphs, or sections contained in this Agreement shall be declared invalid or unenforceable by a valid judgment or decree of a court of competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining phrases, sentences, clauses, paragraphs, or sections of this Agreement which are hereby declared as severable and shall be interpreted to carry out the intent of the parties hereunder unless the invalid provision is so material that its invalidity deprives either party of the basic benefit of their bargain or renders this Agreement meaningless.

9.7 Warranty & Representation of Non-Collusion.

No official, officer, or employee of City has any financial interest, direct or indirect, in this Agreement, nor shall any official, officer, or employee of City participate in any decision relating to this Agreement which may affect his/her financial interest or the financial interest of any corporation, partnership, or association in which (s)he is directly or indirectly interested, or in violation of any corporation, partnership, or association in which (s)he is directly or indirectly interested, or in violation of any State or municipal statute or regulation. The determination of “financial interest” shall be consistent with State law and shall not include interests found to be “remote” or “noninterests” pursuant to Government Code Sections 1091 or 1091.5. Contractor warrants and represents that it has not paid or given, and will not pay or give, to any third party including, but not limited to, any City official, officer, or employee, any money, consideration, or

-27-
01005.0006 2004640.1
other thing of value as a result or consequence of obtaining or being awarded any agreement.

Contractor further warrants and represents that (s)he/it has not engaged in any act(s), omission(s), or other conduct or collusion that would result in the payment of any money, consideration, or other thing of value to any third party including, but not limited to, any City official, officer, or employee, as a result of consequence of obtaining or being awarded any agreement. Contractor is aware of and understands that any such act(s), omission(s) or other conduct resulting in such payment of money, consideration, or other thing of value will render this Agreement void and of no force or effect.

Contractor’s Authorized Initials _______

9.8 Corporate Authority.

The persons executing this Agreement on behalf of the parties hereto warrant that (i) such party is duly organized and existing, (ii) they are duly authorized to execute and deliver this Agreement on behalf of said party, (iii) by so executing this Agreement, such party is formally bound to the provisions of this Agreement, and (iv) the entering into this Agreement does not violate any provision of any other Agreement to which said party is bound. This Agreement shall be binding upon the heirs, executors, administrators, successors and assigns of the parties. [SIGNATURES ON FOLLOWING PAGE]

-28-
01005.0006 2004640.1
IN WITNESS WHEREOF, the parties hereto have executed this Agreement on the date and year first-above written.

CITY:

CITY OF IRWINDALE, a California
charter city
Julian A. Miranda, City Manager
ATTEST:

Laura M. Nieto, Chief Deputy City Clerk
APPROVED AS TO FORM:

ALESHIRE & WYNDER, LLP
Adrian Guerra, City Attorney
CONTRACTOR:

AC Pros, Inc. .
*By: _______________________________
Name: _____________________________
Title: _____________________________
*By: _______________________________
Name: _____________________________
Title: _____________________________
Address: 7046 Darby Avenue
Reseda, CA 91335 .
*Two corporate officer signatures required when Contractor is a corporation, with one signature required from each of the following groups: 1) Chairman of the Board, President or any Vice President; and 2) Secretary, any Assistant Secretary, Chief Financial Officer or any Assistant Treasurer. CONTRACTOR’S

SIGNATURES SHALL BE DULY NOTARIZED, AND APPROPRIATE ATTESTATIONS SHALL BE

INCLUDED AS MAY BE REQUIRED BY THE BYLAWS, ARTICLES OF INCORPORATION, OR OTHER RULES OR REGULATIONS APPLICABLE TO CONTRACTOR’S BUSINESS ENTITY.

01005.0006 2004640.1

CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT

STATE OF CALIFORNIA

COUNTY OF LOS ANGELES
On __________, 2025 before me, ________________, personally appeared ________________, proved to me on the basis of satisfactory evidence to be the person(s) whose names(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.

I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.

WITNESS my hand and official seal.

Signature: _____________________________________

OPTIONAL
Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form

CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT

INDIVIDUAL

CORPORATE OFFICER
_______________________________

TITLE(S)

PARTNER(S) LIMITED

GENERAL

ATTORNEY-IN-FACT

TRUSTEE(S)

GUARDIAN/CONSERVATOR
OTHER_______________________________
______________________________________
SIGNER IS REPRESENTING:
(NAME OF PERSON(S) OR ENTITY(IES))
_____________________________________________
_____________________________________________
___________________________________

TITLE OR TYPE OF DOCUMENT
___________________________________

NUMBER OF PAGES
___________________________________

DATE OF DOCUMENT
___________________________________

SIGNER(S) OTHER THAN NAMED ABOVE
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy or validity of that document.

01005.0006 2004640.1

CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT

STATE OF CALIFORNIA

COUNTY OF LOS ANGELES
On __________, 2025 before me, ________________, personally appeared ________________, proved to me on the basis of satisfactory evidence to be the person(s) whose names(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.

I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.

WITNESS my hand and official seal.

Signature: _____________________________________

OPTIONAL
Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form

CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT

INDIVIDUAL

CORPORATE OFFICER
_______________________________

TITLE(S)

PARTNER(S) LIMITED

GENERAL

ATTORNEY-IN-FACT

TRUSTEE(S)

GUARDIAN/CONSERVATOR
OTHER_______________________________
______________________________________
SIGNER IS REPRESENTING:
(NAME OF PERSON(S) OR ENTITY(IES))
_____________________________________________
_____________________________________________
___________________________________

TITLE OR TYPE OF DOCUMENT
___________________________________

NUMBER OF PAGES
___________________________________

DATE OF DOCUMENT
___________________________________

SIGNER(S) OTHER THAN NAMED ABOVE
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy or validity of that document.

01005.0006 2004640.1

EXHIBIT A

SCOPE OF SERVICES
I. Contractor will perform construction services related to the Irwindale Recreation Center HVAC Replacement Project, which is identified in the City’s Capital Improvement Program, in accordance with the City’s plans and specifications and as set forth in the Contractor’s Bid Documents which are incorporated herein by this reference as though set forth in full, including, but not limited to, the following summary (herein after referred to collectively as “Services”):

The removal and replacement of five (5) rooftop HVAC units that have reached the end of their service life. The new units will be Carrier-manufactured models, each with a minimum Seasonal Energy Efficiency Ratio (SEER) rating of 13, as required by the specifications. Each unit will also be equipped with a carbon monoxide (CO) sensor and an economizer to enhance energy efficiency and safety.

Additionally, the Contractor will resize and modify the existing outdoor metal ductwork to accommodate the new units. All sheet metal caps will also be replaced with new ones as part of the scope of work.

II. As part of the Construction Services, Contractor will deliver the following tangible work products to the City:

A. General overhead & mobilization/demobilization
B. Complete turnkey installation of a 3 Ton Carrier 48FEGA04A2A5-0A0A0 per bid specification
C. Complete turnkey installation of a 5 Ton Carrier 48FEGA06A2A5-0A0A0 per bid specification
D. Complete turnkey installation of a 12.5 Ton Carrier 48FEDM14A3A5-0A0A0 per bid specification
E. Complete turnkey installation of a 3 Ton Carrier 48FEGA04A2A5-0A0A0 per bid specification
F. Complete turnkey installation of a 5 Ton Carrier 50FEQA06A2A5-0A0A0 heat pump unit per bid specification
III. All work product is subject to review and acceptance by the City, and must be revised by the Consultant without additional charge to the City until found satisfactory and accepted by City.

01005.0006 2004640.1

EXHIBIT B

SPECIAL REQUIREMENTS
(Superseding Contract Boilerplate)
If the Parties wish to revise provisions in the Agreement above (from page 1 through the signature page), then the revisions shall be presented in this Exhibit B, with deletions shown in strike through and additions shown in bold and italics.

01005.0006 2004640.1

EXHIBIT C

SCHEDULE OF COMPENSATION
I. Contractor shall complete work for the Project in accordance with the following:

II. The City will compensate Contractor for work performed and expenses incurred toward completion of the Project upon submission of a valid invoice. In addition to what is required under Section 2.2 of the Agreement, each invoice is to include:

A. Line items for all personnel describing the work performed.

B. Line items for all materials and equipment properly charged to the Project.

C. Line items for the price and quantity of all materials, equipment and work.

D. Line items for all other approved reimbursable expenses claimed, with supporting documentation.

01005.0006 2004640.1
E. Line items for all approved subcontractor labor, supplies, equipment, materials, and travel properly charged to the Project.

III. The total compensation for the Project shall not exceed $196,180.00 as provided in Section 2.1 of this Agreement.

01005.0006 2004640.1

EXHIBIT D

PERFORMANCE BOND
PROJECT NO. ________
We, _________, as Principal, and ____________, as Surety, jointly and severally, firmly bind ourselves, our heirs, representatives, successors and assigns, as set forth herein, to the City of Irwindale (“City”) for payment of the penal sum of __________ U.S. Dollars and ____ Cents ($_______). City and Principal have entered into an agreement, or are about to enter into the agreement attached hereto and incorporated by reference herein, for completion of public works for the property(ies) referenced in said agreement. Surety herein approves of the terms and conditions of said agreement and binds itself to faithfully perform the obligations of Principal therein if Principal fails to so perform. Surety acknowledges that the agreement herein referenced shall be that document as executed by City and Principal.

THE CONDITION OF THIS OBLIGATION IS SUCH that if the Principal shall in all things stand to and abide by, and well and truly keep and perform all of the covenants, conditions, and provisions in said agreement, and any alteration thereof made as therein provided, on Principal's part to be kept and performed at the time and in the manner therein specified, and shall indemnify and save harmless the City, City’s engineer, and their consultants, and each of their officials, directors, officers, employees and agents, as therein stipulated, then this obligation shall become null and void; otherwise, it shall be and remain in full force and effect.

Surety agrees that should it fail to take over and diligently perform the agreement upon Principal's default after notice and within the time specified in the agreement, Surety will promptly on demand deposit with City such amount as City may reasonably estimate as the cost of completing all of Principal's obligations. Surety's obligation for payment herein shall exist, notwithstanding any controversy between Principal and City regarding Principal's failure under the agreement, and payment by Surety should be conclusively presumed between the parties herein to relieve, as demanded, Surety's obligations herein and shall be deemed proper payment as between Principal and Surety.

Surety agrees that no change, extension of time, alteration, or addition to the terms of the agreement, or the work to be performed thereunder or the plans and specifications, or any matters unknown to Surety which may affect Surety's risk shall in any wise affect its obligation on this bond, and it does thereby waive notice thereof.

Principal and Surety agree that if the City is required to engage the services of an attorney in connection with the enforcement of this bond, each shall pay City's reasonable attorneys' fees incurred, with or without suit, in addition to the above sum.

01005.0006 2004640.1
Executed this day of _________, ____.

Seal of Corporation _____________
By:____________________________________
Authorized Representative of Principal
Title: _____________
(ATTACH ACKNOWLEDGEMENT OF AUTHORIZED REPRESENTATIVES)
Any claims under this bond may be addressed to: (check one) Surety's agent for service
of process in California: ( ) _____________________
[name of surety company]
_________________________ ____________________________________ Name Street Number
_________________________ ____________________________________ Street Number City and State
_________________________ ____________________________________ City and State Telephone Number
_________________________
Telephone Number
By:____________________________________
Attorney in Fact or other
Representative
(ATTACH ACKNOWLEDGEMENT OF AUTHORIZED REPRESENTATIVE)
Furnish the name, address and phone number of the company agent as well as the surety company.

Sureties must be authorized to do business in and have an agent for service of process in California and be on the accredited list of the United States Treasury Department (their bonds will be limited to such amounts as would be acceptable to the Treasury Department), and otherwise meet the requirements of the agreement.

01005.0006 2004640.1

EXHIBIT E

PAYMENT BOND
PROJECT NO. ________
We, ______, as Principal, and ____________, as Surety, jointly and severally, firmly bind ourselves, our heirs, representatives, successors and assigns, as set forth herein, to the City of Irwindale (“City”) and those for whose benefit this bond insures in the sum of ______________ U.S. Dollars and ______ Cents ($________). City and Principal have entered into an agreement, or are about to enter into the agreement attached hereto and incorporated by reference herein, for completion of public works for the property(ies) referenced in said agreement. Surety herein approves of the terms and conditions of said agreement and binds itself to faithfully perform the obligations of Principal therein if Principal fails to so perform. Surety acknowledges that the agreement herein referenced shall be that document as executed by City and Principal. If Principal or any of Principal's contractors or subcontractors, fails to pay any of the persons named in Section 9000 et seq. of the California Civil Code employed in the performance of the agreement for materials furnished or for labor thereon of any kind, or for amounts due under the Unemployment Insurance Code with respect to such work or labor, then Surety shall pay the same in an amount not exceeding the sum specified above, and also shall pay, in case suit is brought upon this bond, such reasonable attorneys' fees as shall be fixed by the court.

Surety agrees that it shall pay the amounts due the persons above named and diligently perform the agreement upon Principal's default after notice and within the time specified in the agreement.

If Surety fails to perform within the times specified in the agreement, Surety shall promptly on demand deposit with City such amount as City may reasonably estimate as the cost of completing all of Principal's obligations. Surety's obligation for payment herein shall extend, notwithstanding any controversy between Principal and City regarding Principal's failure under the agreement.

Principal and Surety agree that any payment by Surety pursuant to this paragraph should be conclusively presumed between the parties herein to relieve, as demanded, Surety's obligation herein and shall be deemed proper payment as between Principal and Surety.

This bond shall insure to the benefit of any and all of the persons named in Section 9000 et seq. of the California Civil Code so as to give a right of action to them or their assigns in any suit brought upon this bond.

Surety agrees that no change, extension of time, alteration, or addition to the terms of the agreement, or the work to be performed thereunder, or the plans and specifications, or any matters unknown to Surety which might affect Surety's risk, shall in any way affect its obligation on this bond, and it does hereby waive notice thereof.

Principal and Surety agree that should City become a party to any action on this bond, that each will also pay City's reasonable attorneys' fees incurred therein in addition to the above sums.

01005.0006 2004640.1
Executed this _____________ day of ___________, ______.

Seal of Corporation ______________
By:______________________________
Authorized Representative of Principal
Title: __________
(ATTACH ACKNOWLEDGEMENT OF AUTHORIZED REPRESENTATIVES)
Any claims under this bond may be addressed to: (check one) Surety's agent for service
of process in California: ( ) ________________
[name of surety]

_________________________ _____________________________ Name Street Number
_________________________ _____________________________ Street Number City and State
_________________________ _____________________________ City and State Telephone Number
_________________________
Telephone Number
By:_____________________________
Attorney in Fact or other
Representative
(ATTACH ACKNOWLEDGEMENT OF AUTHORIZED REPRESENTATIVE)
Furnish the name, address and phone number of the company agent as well as the surety company.

Sureties must be authorized to do business in and have an agent for service of process in California and be on the accredited list of the United States Treasury Department (their bonds will be limited to such amounts as would be acceptable to the Treasury Department), and otherwise meet the requirements of the agreement.

IRWINDALE CITY COUNCIL CHAMBERS MARCH 12 2025
5050 N. IRWINDALE AVENUE WEDNESDAY
IRWINDALE, CALIFORNIA 91706 7:53 P.M.

The Irwindale SUCCESSOR AGENCY TO THE IRWINDALE COMMUNITY REDEVELOPMENT AGENCY met in regular session at the above time and place.

ROLL CALL: Present: Councilmembers Albert F. Ambriz, Mark A. Breceda, Manuel R. Garcia, Mayor Pro Tem H. Manuel Ortiz;
Mayor Larry G. Burrola
Also Present: Julian A. Miranda, City Manager; Adrian Guerra, City Attorney; Theresa Olivares, Assistant City Manager; Christopher Hofford, Chief of Police; Kambiz Borhani, Director of Finance / City Treasurer; Marilyn Simpson, Community Development Director; Eddie Chan, Director of Engineering / Building Official; Elizabeth Rodriguez, Public Services Director; Mary Hull, Human Resources Manager, and Laura Nieto, Chief Deputy City Clerk
AB 2449 DISCLOSURES None.

CONSENT CALENDAR
MOTION A motion was made by Councilmember Ambriz, seconded by Councilmember Breceda, to approve the Consent Calendar. The motion was unanimously approved; Mayor Pro Tem Ortiz abstaining on Item No. 27A.

ITEM NO. 27A MINUTES OF THE REGULAR MEETING HELD JANUARY 22, 2025

MINUTES OF THE
REGULAR MEETING The minutes of the regular meeting held January 22, 2025, were HELD JANUARY 22, approved.
2025
ITEM NO. 27B AWARD A PROFESSIONAL SERVICES CONTRACT FOR ANNUAL

AWARD A AUDIT SERVICES

PROFESSIONAL
SERVICES CONTRACT The extension of the existing contract with LSL, LLP, to provide FOR ANNUAL annual audit services for five additional years, was approved.

END OF CONSENT CALENDAR

SPONTANEOUS
COMMUNICATIONS There were no speakers.

NEW BUSINESS
ITEM NO. 29A ANNUAL COMPREHENSIVE FINANCIAL REPORT FOR THE ANNUAL FISCAL YEAR ENDED JUNE 30, 2024

COMPREHENSIVE

FINANCIAL REPORT

FOR THE FY ENDED
JUNE 30, 2024

SUCCESSOR AGENCY MINUTES MARCH 12, 2025
REGULAR MEETING PAGE 2
DIRECTOR BORHANI Director Borhani introduced Ryan Domino with Lance, Soll, and Lunghard, LLP, who made a PowerPoint presentation.

MOTION A motion was made by Mayor Pro Tem Ortiz, seconded by Councilmember Breceda, to receive and file the Annual
Comprehensive Financial Report and Supplemental Audit Letters for the Fiscal Year ended June 30, 2024. The motion was unanimously approved.

ADJOURNMENT There being no further business to conduct, the meeting was adjourned at 7:54 p.m.
________________________________
Laura M. Nieto, MMC
Chief Deputy City Clerk

City of Irwindale as Successor Agency to the
Irwindale Community Redevelopment Agency
206.25
Accounts Payable
Checks by Date - Summary by Check Number
Check No Vendor No Vendor Name
Report Total (1 checks): 206.25
Check Date Check Amount
104725 ROSENO RSG Inc. 04/22/2025

IRWINDALE CITY COUNCIL CHAMBERS MARCH 12, 2025
5050 N. IRWINDALE AVENUE WEDNESDAY
IRWINDALE, CALIFORNIA 91706 7:54 P.M.

The Irwindale HOUSING AUTHORITY met in regular session at the above time and place.

ROLL CALL: Present: Board Members Albert F. Ambriz, Mark A. Breceda, Manuel R. Garcia; Vice Chair H. Manuel Ortiz; Chair Larry G. Burrola Also present: Julian A. Miranda, Executive Director; Adrian Guerra, General Counsel; Theresa Olivares, Assistant Executive Director; Christopher Hofford, Chief of Police; Kambiz Borhani, Director of Finance / City Treasurer; Marilyn Simpson, Community Development Director; Elizabeth Rodriguez, Public Services Director; Eddie Chan, Director of Engineering / Building Official; Mary Hull, Human Resources Manager, and Laura Nieto, Chief Deputy City Clerk AB 2449 DISCLOSURES None.

CONSENT CALENDAR
MOTION A motion was made by Board Member Breceda, seconded by Board Member Ambriz, to approve the Consent Calendar. The motion was unanimously approved; Board Member Breceda abstaining on Item No. 33B.

ITEM NO. 33A AWARD PROFESSIONAL SERVICES CONTRACT FOR ANNUAL

AWARD AUDIT SERVICES

PROFESSIONAL
SERVICES CONTRACT The extension of the existing contract with LSL, LLP, to provide annual FOR ANNUAL AUDIT audit services for an additional five years was approved.

SERVICES
ITEM NO. 33B RESOLUTION NO. HA 2025-02-146, ENTITLED: “A RESOLUTION

RESOLUTION RE OF THE BOARD OF DIRECTORS OF THE IRWINDALE HOUSING USE OF 10-ACRE SITE AUTHORITY AUTHORIZING AND APPROVING THE USE OF THE ON ALLEN DRIVE FOR 10-ACRE SITE ON ALLEN DRIVE, ASSESSOR’S PARCEL THE JULY 4, 2025, NUMBER 8417-34-912, FOR THE CITY OF IRWINDALE’S JULY 4, FIREWORKS DISPLAY 2025, FIREWORKS DISPLAY SPECTACTULAR EVENT,” RESOLUTION NO Resolution No. HA 2025-02-146, entitled:

HA 2025-02-146
ADOPTED “A RESOLUTION OF THE BOARD OF DIRECTORS OF THE

IRWINDALE HOUSING AUTHORITY AUTHORIZING AND
APPROVING THE USE OF THE 10-ACRE SITE ON ALLEN DRIVE,
ASSESSOR’S PARCEL NUMBER 8417-34-912, FOR THE CITY OF
IRWINDALE’S JULY 4, 2025, FIREWORKS DISPLAY
SPECTACULAR EVENT,” was adopted.

END OF CONSENT CALENDAR

HOUSING AUTHORITY MINUTES MARCH 12, 2025
REGULAR MEETING PAGE 2

SPONTANEOUS
COMMUNICATIONS There were no speakers.

ADJOURNMENT There being no further business to conduct, the meeting was adjourned at 7:56 p.m.
_________________________
Laura M. Nieto, MMC
Chief Assistant Authority Secretary