CITY OF MARYSVILLE
PUBLIC WORKS DEPARTMENT
CONTRACT AGREEMENT
CDBG PAVEMENT REHABILITATION - PHASE 3 PROJECT
CONTRACT NO. 24-10
THIS AGREEMENT, made and concluded this ____ day of _________________ 2026, between the City of Marysville, party of the first part, and Lamon Construction Co., Inc., Contractor, party of the second part.
ARTICLE I. – WITNESSETH, that for and in consideration of the payments and agreements hereinafter mentioned to be made and performed by the said party of the first part under the conditions expressed in the two bonds bearing even date with these presents and hereunto annexed, the said party of the second part agrees with the said party of the first part, at his own proper cost and expense, to do all the work and furnish all the materials, except such as are mentioned in the specifications to be furnished by said party of the first part, necessary to construct and complete in a good, workmanlike and substantial manner and to the satisfaction of the PUBLIC WORKS DEPARTMENT, construction on various roads, all in accordance with the Special Provisions hereto annexed and also in accordance with the Standard Specifications of the State of California Department of Transportation dated May 2022 the Standard Plans dated May 2022, the “Labor Surcharge” and “Equipment Rental Rates” in effect on the date the work is accomplished, and the “General Prevailing Wage Rates” of the State of California Department of Transportation, which said Special Provisions, Standard Plans, Standard Specifications are hereby specially referred to and by such reference made a part hereof.
The Special Provisions and the project plans for the work to be done are entitled:
CDBG PAVEMENT REHABILITATION - PHASE 3 PROJECT
Which are hereby made part of this contract.
ARTICLE II. – The said Contractor agrees to receive and accept the following prices as full compensation for furnishing all materials and for doing all the work contemplated and embraced in this Agreement; also for all loss or damage arising out of the nature of the work aforesaid, or from the action of the elements, or from any unforeseen difficulties or obstructions which may arise or be encountered in the prosecution of the work until its acceptance by the City of Marysville and for all risks of every description connected with the work; also for all expenses incurred by or in consequence of the suspension or discontinuance of work and for well and faithfully completing the work, and the whole thereof, in the manner and according to the plans and specifications and the requirements of the Engineer under them, to wit.
ARTICLE III. – The said party of the first part hereby promises and agrees with the said Contractor to employ, and does hereby employ, the said Contractor to provide the materials and to do the work according to the terms and conditions herein contained and referred to, for the prices hereinafter set forth, and hereby contracts to pay the same at the City of Marysville Contract Agreement CDBG PAVEMENT REHABILITATION - PHASE 3 PROJECT
time, in the manner and upon the conditions above set forth; and the said parties for themselves, their heirs, executors, administrators, successors and assigns, do hereby agree to the full performance of the covenants herein contained.
ARTICLE IV. – By my signature hereunder, as Contractor, I certify that I am aware of the provisions of Section 3700 of the Labor Code which requires every employer to be insured against liability for Workers Compensation or to undertake self-insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the work of this contract.
ARTICLE V. – It is further expressly agreed by and between the parties hereto that should there be any conflict between the terms of this instrument and the bid or proposal of said Contractor, then this instrument shall control and nothing herein shall be considered as an acceptance of the said terms of said proposal conflicting herewith.
ARTICLE VI. – The City of Marysville hereby employs Contractor to provide material and to do the work according to the terms and conditions herein contained and referred to for the following prices to be paid at the time, in the manner and upon the conditions hereinafter set forth.
ARTICLE VII. – The improvement contemplated in the performance of this contract is an improvement over which the City of Marysville shall exercise general supervision.
ARTICLE VIII. – The statement of prevailing wages appearing in the General Prevailing Wage Rates is hereby specifically referred to and by this reference is made a part of this contract. Wage rates include the highest wage compared between State and Federal Prevailing wage for the identified classifications. It is further expressly agreed, by and between the terms of this instrument and the bid or proposal of said Contractor, that this instrument shall control and nothing herein shall be considered as an acceptance of the said terms of said proposal conflicting herewith.
ARTICLE IX. – The Labor Compliance Manual and Contract Language and the Section 3 Manual are hereto made part of this contract by this reference and if any conflict is evident the highest level of compliance shall prevail. Contractor shall comply with all requirements as outlined in said manuals as provided and in compliance with the funding requirements.
City of Marysville Contract Agreement CDBG PAVEMENT REHABILITATION - PHASE 3 PROJECT
Item
No.
Item Description Estimated
Quantity Unit Unit Price ($/Unit)
Amount
($)
1 Grind 10' taper 0.15' Min. Depth at Edges & Profile as Necessary 596,600 SF
$0.29 $173,014.00
2 Pavement Repair (4" HMA) 6,500 SF $7.00 $45,500.00
3 Geosynthetic Pavement Interlayer (Paving Fabric with Oil) 57,130 SY $2.66 $151,965.80 4 Hot Mix Asphalt (HMA) (Type A) (2" Min. Overlay) 1,920 TON $104.90 $201,408.00 5 Hot Mix Asphalt (HMA) (Type A) (2" Min. Overlay with
Leveling Course) 8,810 TON
$112.00 $986,720.00
6 Type II Slurry Seal 107,000 SF $0.50 $53,500.00
7 Accessible Ramp (Single Corner - Case A) D1 2 EA $10,100.00 $20,200.00 8 Accessible Ramp (Single Through - Case F) D2 8 EA $10,260.00 $82,080.00 9 Accessible Ramp (Double Through - Case F) D3 14 EA $11,780.00 $164,920.00 10 Accessible Ramp (Double Through - Case F with new DIs ) D3 9 EA $11,610.00 $104,490.00
11 Accessible Ramp (Double Corner - Case C) D7 1 EA $11,920.00 $11,920.00 12 Install Truncated Dome Mat in (E) Sidewalk / Ramp Area 36 EA $580.00 $20,880.00 13 Install HMA Speed Table After Overlay with Paving Markings and Waring Signs 2 EA
$15,670.00 $31,340.00
14 Replace Commercial Driveway 4 EA $15,100.00 $60,400.00 15 Replace Minor Concrete (Curb and Gutter) 336 LF $180.00 $60,480.00 16 Minor Concrete - Remove & Replace Sidewalk 3,255 SF $30.00 $97,650.00 17 Replace minor street approach including sidewalk & curb & gutter 24 EA
$13,260.00 $318,240.00
18 Adjust Utility Manhole Covers to grade 30 EA $1,280.00 $38,400.00 19 Adjust Utility (Valve /Cleanout) Covers to grade 45 EA $870.00 $39,150.00 20 Adjust Drain Inlet to grade 21 EA $870.00 $18,270.00 21 Replace Drain Inlet 1 EA $2,550.00 $2,550.00
22 Adjust Centerline Monument Covers to grade (Protect
monument in place) 13 EA
$870.00 $11,310.00
23 Remove Temporary Traffic Circle 1 LS $5,800.00 $5,800.00 24 Pavement Delineation ("STOP" Legend and Stop Bar) 36 EA $600.00 $21,600.00 25 Pavement Delineation ("YIELD" Legend and line arrows) 3 EA $600.00 $1,800.00 26 Pavement Delineation Crosswalk (Detail A24F - Ladder) 61 EA $2,700.00 $164,700.00 27 Pavement Delineation (Detail 22 ) 9,250 LF $1.60 $14,800.00 28 Pavement Delineation (Detail 39 / 39A) 17,100 LF $1.20 $20,520.00 29 Pavement Delineation (2' wide Bike lane buffer - Detail 39 / Diagonal @ 6' O.C.) 15,900 EA
$3.25 $51,675.00
30 Pavement Delineation (Bike Lane Symbol w/ Arrow) 109 EA $172.80 $18,835.20 31 Pavement Delineation (Bike Lane Share Arrow) 7 EA $172.80 $1,209.60 32 Pavement Delineation (TYPE I, II, & II Arrows) 18 EA $540.00 $9,720.00 33 Pavement Delineation - Diagonal Parking Lines 169 EA $75.60 $12,776.40 34 Bike Path Sign - 1 Post 24 EA $432.00 $10,368.00
35 Replace Street Name Signs 2 - 1 Post 17 EA $440.00 $7,480.00 36 Replace Street Name Sign - 1 Post 12 EA $405.00 $4,860.00 37 Replace Stop Sign - 1 Post 36 EA $432.00 $15,552.00
38 Replace Yield Sign - 1 Post 3 EA $475.00 $1,425.00
39 Replace Caltrans Signal Loops 2 EA $3,780.00 $7,560.00 40 Replace Caltrans Advanced Signal Loops 2 EA $3,780.00 $7,560.00 $3,072,629.00
Mobilization / Demobilization = $18,560.00
SWPPP = $11,780.00
Traffic Control = $86,280.00
$3,189,249.00
Bid Schedules A1 - A8 combined
Total Bid Schedules A1 - A8 =
Total Base Bid (Schedules A1 - A8) =
City of Marysville Contract Agreement CDBG PAVEMENT REHABILITATION - PHASE 3 PROJECT
Approved as to form:
City Attorney
City of Marysville
CITY OF MARYSVILLE
Jim Schaad
City Manager
Date
CONTRACTOR
Company Name
By and Title (signature)
Date
By and Title (printed)
Address
Telephone Number
CITY OF MARYSVILLE
PUBLIC WORKS DEPARTMENT
BOND OF FAITHFUL PERFORMANCE
CDBG PAVEMENT REHABILITATION - PHASE 3 PROJECT
CONTRACT NO. 24-10
KNOW ALL MEN BY THESE PRESENTS, THAT WE, ________________________, the Contractor in the contract hereto annexed, as principal, and ______________________, as surety, are held and firmly bound unto the City of Marysville in the sum of _______________________________________________ ($________________) lawful money of the United Stated, for which payments, well and truly to be made, we bind ourselves, jointly and severally, firmly by these presents.
Signed, sealed and dated ________________________________________.
The condition of the above obligation is that if said principal, as Contractor in the contract hereto annexed, shall faithfully perform each and all of the conditions of said contract to be performed by him, and shall furnish all tools, equipment, apparatus, facilities, transportation, labor and material, other than material, if any, agreed to be furnished by the City, necessary to perform and complete, and to perform and complete in a good workmanlike manner, the work of CDBG PAVEMENT REHABILITATION - PHASE 3 PROJECT, in strict conformity with the terms and conditions set forth in the contract hereto annexed, then this obligation shall be null and void, otherwise to remain in full force and effect, and that said surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration, or addition to the terms of the contract or to the work to be performed thereunder or the specifications accompanying the same, shall in any wise affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration, or addition to the terms of the contract or to the work or to the specifications.
Surety further agrees, in case suit is brought upon this bond, that it will pay, in addition to the basic obligation herein, a reasonable attorney’s fee to be awarded and fixed by the Court and to be taxed as costs and to be included in the judgment therein rendered.
Contractor
Surety
Approved as to form:
City Attorney
City of Marysville
CITY OF MARYSVILLE
PUBLIC WORKS DEPARTMENT
PAYMENT BOND
(Section 9550, Civil Code)
CDBG PAVEMENT REHABILITATION - PHASE 3 PROJECT
CONTRACT NO. 24-10
WHEREAS, the City of Marysville, PUBLIC WORKS DEPARTMENT, hereafter referred to as “Obligee,” has awarded to Contractor, _________________________, hereinafter referred to as “Principal,” a contract for the work described as follows:
CDBG PAVEMENT REHABILITATION - PHASE 3 PROJECT
.
AND, WHEREAS, said Principal is required to furnish a bond in connection with said contract, to secure the payment of claims of laborers, mechanics, materialmen, and other persons as provided by law.
NOW, THEREFORE, we the undersigned Principal and Surety are bound unto the Obligee in the sum of ______________________________________________($___________) for which payment we bind ourselves, jointly and severally.
THE CONDITION OF THIS OBLIGATION IS SUCH
That if said Principal or its subcontractors shall fail to pay any of the persons named in Civil Code Section 9100, or amounts due under the Unemployment Insurance Code with respect to work or labor performed by such claimant, or any amounts required to be deducted, withheld, and paid over to the Franchise Tax Board from the wages of employees of the Principal and his subcontractors pursuant to Section 18806 of the Revenue and Taxation Code, with respect to such work and labor, that the surety herein will pay for the same in an amount not exceeding the sum specified in this bond, otherwise the above obligation shall be void. In case suit is brought upon this bond, the surety will pay a reasonable attorney’s fee to be fixed by the court.
This bond shall inure to the benefit of any of the persons named in Civil Code Section 9100 as to give a right of action to such persons or their assigns in any suit brought upon this bond.
Dated: _______________________, 2026
By:
Principal
By:
Attorney-in-Fact