Cities Index.
Agreement and Bonds - IP19-030L

Menifee City Council
February 5, 2025

Document
Agreement and Bonds - IP19-030L
Meeting
February 5, 2025
Body
Menifee City Council
Original file
22.9 MB
Text extracted from the city's file for reading and search. Open the original on cityofmenifee.primegov.com. That file is the official record.

DocuSign Envelope ID: 0897D1D5-8369-413F-92E8-7AF9C4CB90AA

AGREEMENT
Tract Map 31098

FOR THE CONSTRUCTION OF LANDSCAPE IMPROVEMENTS
IP19-030L
This agreement, made and entered into by and between the City of Menifee, State of Califomia, hereinafter called City, and__Lennar Homes of California, Inc., hereinafter called Developer.

WITNESSETH:
accordance with the standards set forth in Riverside County Ordinance No. 460, as amended, or its successor, which are hereby expressly made a part of this agreement. All the above required work shall be done under the inspection of and to the satisfaction of the City Engineer, and shall not be deemed complete until approved and accepted as complete by the City. Developer further agrees to maintain the above required improvements for a period of one year following acceptance by the City, and during this one year period to repair or replace, to the satisfaction of the City Engineer, any defective work or labor done or defective materials fumished. Developer further agrees that all underground improvements shall be completed prior to the paving of any roadway. The estimated cost of said work and improvements is the sum of Four Hundred Sixty Seven Thousand Five Hundred and no/100, Dollars, $ 467,500.00
SECOND: Developer agrees to pay to City the actual cost of such inspections of the work and improvements as may be required by the City Engineer. Developer further agrees that, if suit is brought upon this agreement or any bond guaranteeing the completion of the road and drainage improvements, all costs and reasonable expenses and fees incurred by City in successfully enforcing such obligations shall be paid by Developer, including reasonable attorney's fees, and that, upon entry of judgment, all such costs, expenses and fees shall be taxed as costs and included in any judgment rendered.

THIRD: City shall not, nor shall any officer or employee of City, be liable or responsible for any accident, loss or damage happening or occurring to the works specified in this agreement prior to the completion and acceptance thereof, nor shall City or any officer or employee thereof, be liable for any persons or property injured by reason of the nature of the work, or by reason of the acts or omissions of Developer, its agents or employees, in the performance of the work, and all or said liabilities are assumed by Developer. Developer agrees to protect, defend, and hold harmless City and the officers and employees thereof from all loss, liability or claim because of, or arising out of the acts or omissions of Developer, its agents and employees, in the performance of this agreement or arising out of the use of any patent or patented article in the performance of this agreement.

FOURTH: The Developer hereby grants to City, or any agent or employee of City, the irrevocable permission to enter upon the lands of the subject land division for the purpose of completing the improvements.

This permission shall terminate in the event that Developer has completed work within the time specified or any extension thereof granted by the City.

FIFTH: The Developer shall provide adequate notice and warning to the traveling public of each and every hazardous or dangerous condition caused or created by the construction of the works of improvement at all times up to the completion and formal acceptance of the works of improvement. The Developer shall protect all persons from such hazardous or dangerous conditions by use of traffic regulatory control methods, including, but not limited to, stop signs, regulatory signs or signals, barriers, or detours.

DocuSigri Envelope ID: 0897D1D5-8369-413F-92E8-7AF9C4CB90AA SIXTH: Developer, its agents and employees, shall give notice to the City Engineer at least 48 hours before beginning any work and shall furnish said City of Menifee Engineering all reasonable facilities for obtaining full information with respect to the progress and manner of work.

SEVENTH: If Developer, its agents or employees, neglects, refuses, or fails to prosecute the work with such diligence as to insure its completion within the specified time, or within such extensions of time which have been granted by City, or if Developer violates, neglects, refuses, or fails to perform satisfactorily any of the provisions of the plans and specifications, Developer shall be in default of this agreement and notice of such default shall be served upon Developer. City shall have the power, on recommendation of the City Engineer, to terminate all rights of Developer because of such default. The determination by the City Engineer of the question as to whether any of the terms of the agreement or specifications have been violated, or have not been performed satisfactorily, shall be conclusive upon the Developer, and any and all parties who may have any interest in the agreement or any portion thereof. The foregoing provisions of this section shall be in addition to all other rights and remedies available to City under law. The failure of the Developer to commence construction shall not relieve the Developer or surety from completion of the improvements required by this agreement.
payment of labor and materials in the amount prescribed by Article XVII of Riverside County Ordinance 460 as amended to secure the claims to which reference is made in Title 15 (commencing with Section 3082) of Part 4 of Division 3 of the Civil Code of the State of California. Developer agrees to renew each and every said bond or bonds with good and sufficient sureties or increase the amount of said bonds, or both, within ten (10) days after being notified by the City Engineer that the sureties or amounts are insufficient. Notwithstanding any other provisions herein, if Developer fails to take such action as is necessary to comply with said notice, Developer shall be in default of this agreement unless all required improvements are completed within ninety (90) days of the date on which the City Engineer notified Developer of the insufficiency of the security or the amount of the bonds or both.

NINTH: It is further agreed by and between the parties hereto, including the surety or sureties on the bonds securing this agreement, that, in the event it is deemed necessary to extend the time of completion of the work contemplated to be done under this agreement, extensions of time may be granted, from time to time, by City, either at its own option, or upon request of Developer, and such extensions shall in no way affect the validity of this agreement or release the surety or sureties on such bonds. Developer further agrees to maintain the aforesaid bond or bonds in full force and effect during the terms of this agreement, including any extensions of time as may be granted therein.

TENTH: It is understood and agreed by the parties hereto that if any part, term or provision of this agreement is by the courts held to be unlawful and void, the validity of the remaining portions shall not be affected and the rights and obligations of the parties shall be construed and enforced as if the agreement dic not contain that particular part, term or provision held to be invalid. d, at the following addresses
aver of any ere or contin of this remanen or the paris are to the matters set fort DocuSign Envelope ID: 0897D1D5-8369-413F-92E8-7AF9C4CB90AA City Developer
City of Menifee Lennar Homes of Califomia, Inc.
29844 Haun Road 980 Montecito Dr. Suite 302
Menifee, CA 92586 Corona, CA 92879
IN WITNESS WHEREOF, Landowner has affixed his name, address and seal.

Dated: May th , 2020 Its Manger:

By:
sainste
Ammonzed Arent
By:

Dated: , 2020 CITY OF MENIFEE
By:

Jonathan G. Smith, Public Works Director/
City Engineer

CITY OF MENIFEE
By. Dett
Bill Zimmerman, Mayor
ATTEST: APPROVED AS TO FORM:

By. By:

Sarah Manwaring, City Clerk Jeffery T. Melching, City Attorney

SIGNATURES OF DEVELOPER MUST BE ACKNOWLEDGED BY NOTARY

AND EXECUTED IN TRIPLICATE
DocuSign Envelope ID: 4F57ADCE-A485-4477-83A3-892230D1F193 IN WITNESS WHEREOF, Developer has affixed his name, address and seal.

Dated: _ 2021 By: Developer
Dated: July 21 _. 2021 CITY OF MENIFEE
- Docusigned by:

By: Daniel Padilla
Danier adita, City Engineer

CITY OCESIMENIFEE
By_
Armandon. Villa, City Manager
ATTEST: APPROVED AS TO FORM:
- DocuSigned by: - DocuSigned by:

By Saral d. Manwaring By: Jeffrey t. Melching, City Attorney Sarah A: Manwaring, City Clerk Jefrey. Melching, City Attorney

SIGNATURES OF DEVELOPER MUST BE ACKNOWLEDGED BY NOTARY

ACKNOWLEDGMENT
tate of Californi
ounty of NiverSin
on lay 15, 200 before me, Beth Bruley, notary Public
(insert name and title of the officer)
personally appeared William Sacriste
who proved to me on the basis of satisfactory evidence to be the person(s) whose names) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(les), and that by his/her/their signature(s) on the instrument the persons), or the entity upon behalf of which the person(s) acted, executed the instrument.

I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.

WITNESS my hand and official seal.

BETH BRULEY
Notary Public - California
Riverside County
Commission # 2247751
My Comm. Expires Jul 24, 2022 /
signature BalaBu (Seal)
McCall Mesa

MENIFEE

FAITHFUL PERFORMANCE BOND

CITY OF MENIFEE, STATE OF CALIFORNIA
(Government Code Section 66499.1)
FOR: Landscape $ 176,000.00 Tract Map _TM31098
Irrigation $ 190,500.00 Ref. No. IP19-030L
Construction 58,000.00 Bond No. 024245382
10% Contingency $ 43,000.00
Total $ 467,500.00 Premium $ 1.403.00/annum
Surety Liberty Mutual Insurance Company Principal Lennar Homes of California, Inc.

Address 175 Berkeley Street Address 980 Montecito Dr. Suite 302 City/State Boston, MA City/State Corona, CA
Zip code _ 02116 Zip 92879
Phone (617) 357-9500 Phone (951) 817-3500
WHEREAS, the City of Menifee, State of California, and Lennar Homes of California, Inc. (hereinafter designated as "principal") have entered into, or are about to enter into, the attached agreements) whereby principal agrees to install and complete the above designated public improvements relating to Tract Map 31098 - IP19-030L, which agreements) is/are hereby referred to and made a part hereof; and,
WHEREAS, said principal is required under the terms of said agreements) to furnish bond(s) for the faithful performance of said agreements);
NOW, THEREFORE, we the principal and Liberty Mutual Insurance Company, as surety, are held and firmly bound unto the City of Menifee in the penal sum of Four Hundred Sixty Seven Thousand Five Hundred and no/100, Dollars, $467,500.00 lawful money of the United States, for the payment of which sum will and truly be made, we bind ourselves, our heirs, successors, executors and administrators, jointly and severally, firmly by these presents.

The condition of this obligation is such that if the above bonded principal, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and provisions in the said agreement and any alteration thereof made as therein provided, on his or their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the City of Menifee, its officers, agents and employees, as therein stipulated, then this obligation shall become null and void; otherwise, it shall remain in full force and effect.

As a part of the obligation secured hereby and in addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred by the City in successfully enforcing such obligation, all to be taxed as costs and included in any judgment rendered.

FAITHFUL PERFORMANCE BOND

MENIFEE
The surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of this agreement or to the work to be performed there under or the specifications accompanying the same shall in anywise affect its obligation on this bond, anc it does hereby waive notice of any such change, extension of time, alteration or addition.

Surety further stipulates and agrees that the provisions of Section 2845 of the Civil Code and commencement of construction are not conditions precedent to surety's obligations hereunder and are hereby waived by surety.

When the work covered by the agreement is complete, the City of Menifee will accept the work and thereupon, the amount of the obligation of this bond is reduced by 90% with the remaining 10% held as security for the one-year maintenance period provided for in the agreements(s).

IN WITNESS WHEREOF, this instrument has been duly executed by the principal and surety above named, on May 14, 2020.

NAME OF PRINCIPAL: Lennar Homes of California, Inc., a California corporation AUTHORIZED SIGNATURE(S):

By:

Name: Wilam Cachste
Tite: Authori-ed agent
(IF CORPORATION, AFFIX SEAL)
NAME OF SURETY: Liberty Mutual Insurance Company
AUTHORIZED SIGNATURE:

My kua, yo Atomey in Fact Titie
(IF CORPORATION, AFFIX SEAL)

ATTACH NOTARIAL ACKNOWLEDGMENT OF SIGNATURES OF PRINCIPAL AND ATTORNEY-IN-FACT.

ACKNOWLEDGMENT
A notary public or other officer completing this
ertificate verifies only the identity of the individua
vho signed the document to which this certificate i
attached, and not the truthfulness, accuracy, or
State of Galifornia
county of Killiste
on Mup 5, 20D0 _before me, eth Brutey, notar tublic
(insert name ahd title of the officer)
personally appeared • William Sacriste
who proved to me on the basis of satisfactory evidence to be the person(s) whose names) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(les), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.

I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.

WITNESS my hand and official seal. BETH BRULEY
Notary Public - Callfornia
Riverside County
Commission # 2247751
My Comm, Expires Jul 24, 2022
signature Elu
(Seal)

CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.

State of California
County of Orange
On MAY 14 2020 before me, _ Kathy R. Mair, Notary Public DATE [Name of Notary Public and Title "Notary Public"]
personally appeared My Hua - -- --------
[Name(s) of Signers)]
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(6), or the entity upon behalf of which the person(s) acted, executed the instrument.

I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.

WITNESS my hand and official seal.

KATHY R. MAIR
Notary Public - California
Orange County
Commission # 2193966 Preennai
My Comm. Expires May 22. 2021
Signature of Notary Public
Place Notary Seal Above
- OPTIONAL --
Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document.

Description of Attached Document
Title or Type of Document:

Document Date: Number of Pages:

Signer(s) Other Than Named Above:

Capacity(ies) Claimed by Signer(s)
Signer's Name: My Hua Signer's Name:

Corporate Officer - Title(s): • Corporate Officer - Title(s): - Partner - • Limited • General Partner - • Limited L General Individual X Attorney-in-Fact Individual • Attorney-in-Fact Trustee Guardian or Conservator Trustee • Guardian or Conservator Other: Other:

Signer Is Representing: Signer is Representing:

This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated.

Liberty Liberty Mutual Insurance Company
Mutuál. The Ohio Casualty Insurance Company Certificate No: 8202349-024017 West American Insurance Company
SURETY

POWER OF ATTORNEY
KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casually Insurance Company is a corporation duly organized under (he laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the "Companies"), pursuant to and by authority herein set forth, does hereby name, constiute and appoint, Tenzer V Cunningham, Martha Gonzales, My Hua, Mechelle Larkin, Kathy R. Mair, Joaquin Percz, Regina Rangel, Brenda Wong all of the city of Los Angeies state of Calttornia each individually if there be more than one named, its true and lawful attorney-in-fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons.

IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been afixed thereto this 14th day of October 2019
Liberty Mutual Insurance Company
The Ohio Casually Insurance Company
UTUAL CORPORAT CASUALT INSURANCE COMPORTA West American Insurance Company 1912 1919 1991
ANVaWOD INDIANA
LS3M By:

David M. Carey, Assistant Secretary
State of PENNSYLVANIA
ss
County of MONTGOMERY
On this 14th day of October 2019 before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance letter of credit, Company, The Ohio Casually Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer.

IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at King of Prussia, Pennsylvania, on the day and year first above written. loan, PASTELL COMMONWEALTH OF PENNSYLVANIA
Notarol Seal 1-610-832-8240 between 9:00 am and 4:30 pm EST on any business day currency rate, interest rate or residual value guarantees. Teresa Pastella, Notary Putte Pastella Upper Monon Twp., Mortgomory Gaunly By:

My Commission Expiros March 28,2021 Teresa Pastelia, Notary Public Alember, Pennsylania Association of Nolanes
confirm the validity of this Power of Attorney call
This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casually Insurance Company, Liberty Mutual Not valid for mortgage, note, Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows:

ARTICLE IV - OFFICERS: Section 12, Power of Atlorney.

Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the President may prescribe, shall appoint such attorneys-in-fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowiedge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys-in-fact, subject lo the limitations set forth in their respective powers of attorney, shail have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney-in-fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority.

ARTICLE XIII - Execution of Contracts: Section 5. Surety Bonds and Undertakings Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, H shall appoint such attorneys-in-fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings. bonds, recognizances and other surety obligations. Such attorneys-in-fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary.

Certificate of Designation - The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such attorneys-in- fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surely any and all undertakings, bonds, recognizances and other surety obligations.

Authorization - By unanimous consent of the Company's Board of Dirertors, the Company consents that lacsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any sower of altomey issued by the Company in connection with surety bonds, shall be valid and binding upon lhe Company with the same force and effect as though manually affixert.
1, Renee C. Liewellyn, the undersigned, Assistant Setrelary, The Ohio Casually insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of atlorney of which the foregoing is a full, true and correct copy of the Power of Attorney execuled by said Companies, is in full force and effect and has not been revoked.

IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 14th day of May 2020

INSURAN AT HISURANGE INSURANCE
CUTPORATED MERICAN «CORPORATE
1912 1919 1991 Rai ell
OHIO ATH HAMP SLA By:

ANTON INDIANA Renee C. Lieweliyn, Assistant Secretary
LSEN
LMS-12873 LMIC OCIC WAIC Mulli Co_062018
McCall Mesa

MENIFEE

MATERIAL AND LABOR BOND

CITY OF MENIFEE, STATE OF CALIFORNIA
(Government Code Section 66499.1)
FOR: Landscape $ 88,000.00 Tract Map TM31098
Irrigation $ 95.250.00 Ref. No.. IP19-030L
Construction $ 29,000.00 Bond No.. 024245382
10% Contingency $ 21,500.00
Total $ 233,750.00 Premium included in Performance Bond Surety Liberty Mutual Insurance Company Principal Lennar Homes of California, Inc.

Address 175 Berkeley Street Address 980 Montecito Dr. Suite 302 City/State Boston, MA City/State Corona, CA
Zip code 02116 Zip 92879
Phone_ (617) 357-9500 Phone (951) 817-3500
WHEREAS, the City of Menifee, State of California, and - Lennar Homes of California Inc. , (hereinafter designated as "principal") have entered into, or are about to enter into, the attached agreements) whereby principal agrees to install and complete the above designated public improvements relating to Tract Map 31098 - IP19-30L, which agreements) is/are hereby referred to and made a part hereof; and,
WHEREAS, under the terms of said agreement, principal is required, before entering upon the performance of the work, to file a good and sufficient payment bond with the City of Menifee to secure the claims to which reference is made in Title 15 (commencing with Section 3082) of Part 4 of Division 3 of the Civil Code of the State of California; NOW, THEREFORE, said principal and the undersigned, as corporate surety, are held firmly unto the City of Menifee and all contractors, subcontractors, laborers, material persons and other persons employed in the performance of said Civil Code in the sum of _Two Hundred Thirty Three Thousand Seven Hundred Fifty and no/100 Dollars, § 233.750.00 materials furnished or labor thereon of any kind, or for amounts due under the Unemployment Insurance Act with respect to such work or labor, that said surety will pay the same in an amount not exceeding the amount hereinabove set forth, and also in case suit is brought upon this bond, will pay, in addition to the face amount thereof, costs and reasonable expenses and fees, including reasonable attorney's fees, incurred by the City in successfully enforcing such obligation, to be awarded and fixed by the court, and to be taxed as costs and to be included in the judgment therein rendered.

It is hereby expressly stipulated and agreed upon that this bond shall inure to the benefit of any and all persons, companies and corporations entitles to full claims under Title 15 (commencing with Section 3082) of Part 4 of Division 3 of the Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond.

Should the condition of this bond be fully performed, then this obligation shall become null and void; otherwise, it shall be and remain in full force and effect.

McCall Mesa

MATERIAL AND LABOR BOND
The surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of this agreement or to the specifications accompanying the same shall in anywise affect its obligation on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition. Surety further stipulates and agrees that the provisions of Section 2845 of the Civil Code are not a condition precedent to surety's obligations hereunder and are hereby waived by surety.

IN WITNESS WHEREOF, this instrument has been duly executed by the principal and surety above named, on May 14, 2020..

NAME OF PRINCIPAL: Lennar Homes of California, Inc., a California corporation AUTHORIZED SIGNATURE(S):

By: NOt
Name Wittam saiste
Title: Authonzed Agent
(IF CORPORATION, AFFIX SEAL)
NAME OF SURETY: Liberty Mutual Insurance Company
AUTHORIZED SIGNATURE:

My Hu Its Attorney-in-Fact Titie
(IF CORPORATION, AFFIX SEAL)

ATTACH NOTARIAL ACKNOWLEDGMENT OF SIGNATURES OF PRINCIPAL AND ATTORNEY-IN-FACT.

ACKNOWLEDGMENT
A notary public or other officer completing this
ertificate verifies only the identity of the individua
rho signed the document to which this certificate i
attached, and not the truthfulness, accuracy, or
State of California
County of Killerse
on May 15, 2020 _before me, Both Brutel, notary Pablic
(insert name and title of the officer)
personally appeared William Sacriste
who proved to me on the basis of satisfactory evidence to be the persons) whose names) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(tes), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the personts) acted, executed the instrument.

I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.

WITNESS my hand and official seal.

BETH BRULEY
Notary Public • Californla
Riverside County
Commission # 2247751
My Comm. Explres Jul 24, 2022
Signature (Seal)

CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the locument to which this certificate is attached, and not the truthfulness, accuracy, or validity of that documen State of California
County of _ Orange
On MAY 14 2020 before me, Kathy R. Mair, Notary Public
DATE [Name of Notary Public and Title "Notary Public*]
personally appeared My Hua - - - - - -
(Name(s) of Signer(s)]
who proved to me on the basis of satisfactory evidence to be the person(6) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/theif authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.

I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.
stanistant
KATHY R. MAR WITNESS my hand and official seal.

Notary Public - California
Orange County
Commission # 2193966
My Comm. Expires May 22. 2021 Kansan
Signature of Notgry Public
Place Notary Seal Above
- OPTIONAL
Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document.

Description of Attached Document
Title or Type of Document:

Document Date: Number of Pages:

Signer(s) Other Than Named Above:

Capacity(ies) Claimed by Signer(s)
Signer's Name: My Hua Signer's Name:

Corporate Officer - Title(s): Corporate Officer - Title(s):

Partner - • Limited • General Partner - • Limited • General Individual Attorney-in-Fact Individual • Attorney-in-Fact Trustee Guardian or Conservator Trustee • Guardian or Conservator Other: Other:

Signer Is Representing: Signer is Representing:

This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated.

Liberty Liberty Mutual Insurance Company
Mutuál. The Ohio Casualty Insurance Company Certificate No: 8202349-024017 West American Insurance Company
SURETY

POWER OF ATTORNEY
KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire, that Liberty Mutual insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein colleclively called the "Companies"), pursuant to and by authority herein set forth, does hereby name, conslitute and appoint, Tenzer V Cunningham, Martha Gonzales, My Hua, Mechelle Larkin, Kathy R. Mair, Joaquin Perez, Repina Rangel. Brenda Wong all of the cily of Los Angeles state of California each individually if there be more than one named, its true and lawful altorney-in-fact to make xecute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surely obligations, in pursuanc these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own prop persons.

IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 14th day of October 2019

MUTUAL CASUALTI INSURANCE INSURANCE
«CORPORATE MERICAN
1912 1919 1991
ANTONI ANTON Lait Can
129391 INDIANEL
1S3M By:

David M. Carey, Assistant Secretary
State of PENNSYLVANIA
County of MONTGOMERY SS
On this 14th day of October 2019 before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance Company, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes call therein contained by signing on behalf of the corporations by himself as a duly authorized officer. interest rate or residual value guarantees IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at King of Prussia, Pennsylvania, on the day and year first above written.

PASTELLA of Attornev

COMMONWEALTH OF PENNSYLVANIA
Notarial Stal 1-610-832-8240 between 9:00 am and 4:30 pm EST on any business day. teresa Pasrella. Notary Potlic Teres Pastella
Lipon/ Menio Tup., Montgomery County By: ower
Not valid for mortgage, note, loan, letter of credit, My Cominission Expires March 29.2021 Teresa Pastella, Notary Public Member, Parusylvaria Asscciation af Notaris a.

This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual of this Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows:
itv
ARTICLE IV - OFFICERS: Section 12, Power of Attorney.

Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the validi President may prescribe, shall appoint such attorneys-in-fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety currency rate, any and all undertakings, bonds, recognizances and other surely obligations. Such attomeys-in-fact, subject to the limitations set forth in their respective powers of attorney, shal the have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporalion. When so execuled, such instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney-in-fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or aulhority. confirm ARTICLE XIII - Execution of Contracts: Section 5. Surety Bonds and Undertakings.

Any officer of the Company authorized for that purpose in wiling by the chairman or the president, and subject to such limitalions as the chairman or the president may prescribe, o shall appoint such attorneys-in-fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligalions. Such attomeys-in-fact subject to the limitations set forth in their respective powers of atfomey, shall have full power lo bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary.

Certificate of Designation - The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appont such attorneys-in- fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations.
chorization - By unanimous consent of the Company's Board of Directore, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of mpany, wherever appearing upon a certified copy of any power of altoney issued by the Company in connection with surety bands, shall be valid and binding upon the Company the same force and effect as though manually affixed.
1, Renee C. Llewellyn, the undersigned, Assistant Secretary, The Ohio Casualty Insurance Company, Liberty Mulual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorey of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked.

IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 14th day of May _ 2020

INSUR INSURA INSURANCE

MUTUAL CORPORATE ANCE CASUALTI CAN (CORPORATE
1912 1919 1991
ANYAWO? By:
1283911 3H1 1S3M INDIANA Renee C. Llewellyn. Assistant Secretary LMS-12873 LMIC OCIC WAIC Multi Co_062018

← All documents from this meeting