ATT 1 - Construction Contract & Proposal, R.E. Schultz, Tot Lot Improvements, 04.2024

CITY OF MURRIETA, COMMUNITY SERVICES DEPARTMENT
01375.0001/977105.1 CONTRACT C 1 CITY PROJECT 23-472, TOT LOT REPLACEMENT PROJECT PHASE 2

CONTRACT

TOT LOT IMPROVEMENT PROJECT PHASE 2
CITY PROJECT NO. 23-472
CIP 22029, 22030, 22031, 22032, 22040

THIS CONTRACT, made and entered into the 7th day of May, 2024, by and between the City of Murrieta, a municipal corporation, hereinafter referred to as "CITY," and R.E. Schultz Construction, Inc., hereinafter referred to as "CONTRACTOR." WITNESSETH:

That CITY and CONTRACTOR, for the consideration hereinafter named, mutually agree as follows:

1. C ONTRACT DOCUMENTS . The complete Contract includes all of the Contract Documents, to wit: Notice Inviting Bids, Instructions to Bidders, Proposal, Performance Bond, Labor and Materials Bond, Plans and Special Provisions entitled TOT LOT IMPROVEMENT PROJECT PHASE 2 , Insurance Forms, this Contract, and all modifications and amendments thereto, and the latest version of the Standard Specifications for Public Works Construction, Parts 1 through 6, with the exception of Section 307, "Street Lighting and Traffic Signals," and the addition of the Standard Specifications, Department of Transportation, State of California State Standard Specifications, Section 86, "Signals, Lighting and Electrical Systems," and Section 56, "Signs," dated May 2006.

The P lans consist of:

TOT LOT IMPROVEMENT PROJECT PHASE 2
CITY PROJECT NO. 23-472
Copies of the Standard Specifications for Public Works Construction are available from the publisher:

Building News, Inc. (BNi)
990 Park Center Drive, Suite E
Vista, CA 92081
(760) 734-1113
www.bnibooks.com
The aforementioned Standard Specifications will control the general provisions, construction materials, and construction methods for this Contract except as amended by the Plans and Specifications of this Contract.

In case of conflict between the Standard Specifications for Public Works Construction or State Standard Specifications, and the remaining Contract Documents, the remaining Contract Documents shall take precedence over and be used in lieu of such conflicting portions.

Where the Plans or Specifications describe portions of the work in general terms, but not in complete detail, it is understood that the item is to be furnished and installed completed and in place and that only the best general practice is to be used.

CITY OF MURRIETA, COMMUNITY SERVICES DEPARTMENT
01375.0001/977105.1 CONTRACT C 2 CITY PROJECT 23-472, TOT LOT REPLACEMENT PROJECT PHASE 2

Unless otherwise specified, CONTRACTOR shall furnish all labor, materials, tools, equipment, and incidentals, and do all the work involved in executing the Contract.

The Contract Documents are complementary, and what is called for by anyone shall be as binding as if called for by all. Any conflict between this Contract and any other Contract Document shall be resolved in favor of this Contract.

2. S COPE OF WORK . CONTRACTOR shall perform the work as shown on the Contract Drawings, shall furnish all the labor, materials, necessary tools, expendable equipment, and all utility and transportation services required for the completion of the following project:

TOT LOT IMPROVEMENT PROJECT PHASE 2
CITY PROJECT NO. 23-472
CIP 22029, 22030, 22031, 22032, 22040
All of said work to be performed and materials to be furnished shall be in strict accordance with the Drawings and Specifications and the provisions of the Contract Documents hereinabove enumerated and adopted by CITY.

3. CITY APPROVAL . All labor, materials, tools, equipment, and services shall be furnished and work performed and completed under the direction and supervision and subject to the approval of CITY or its authorized representatives.

4. C ONTRACT AMOUNT AND SCHEDULE . CITY agrees to pay and Contractor agrees to receive and accept the prices set forth in the proposal as full compensation for furnishing all materials, performing all work, and fulfilling all obligations hereunder.

Said compensation shall cover all expenses, losses, damages, and consequences arising out of the nature of the work during its progress or prior to its acceptance, including those for well and faithfully completing the work and the whole thereof in the manner and time specified in the aforesaid contract documents and also including those arising from actions of the elements, unforeseen difficulties or obstructions encountered in the prosecution of the work, suspension or discontinuance of the work, and all other unknowns or risks of any description connected with the work.

CONTRACTOR ag rees to complete the work on TOT LOT IMPROVEMENT PROJECT PHASE 1 in a period not to exceed Seventy -Five (75) working days per Section 6-7 of the Standard Specifications for Public Work Construction, commencing upon the date stated in the Notice to Proceed by CITY. Construction shall not commence until bonds and insurance are approved by CITY.

5. C HANGE ORDERS. All change orders shall be approved by the City Council, except that the City Manager or his designee is hereby authorized by the City Council to make, by written order, changes or additions to the work in an amount not to exceed fifteen (15) p ercent of this Contract amount and the City Manager or his designee shall notify City Council in a public meeting if changes or additions to the work exceed ten (10) percent of this Contract amount.

CITY OF MURRIETA, COMMUNITY SERVICES DEPARTMENT
01375.0001/977105.1 CONTRACT C 3 CITY PROJECT 23-472, TOT LOT REPLACEMENT PROJECT PHASE 2

6. PAYMENTS/ACCEPTANCE OF WORK. The text of Subsection 9- 3.2 of the Standard Specifications for Public Works Construction is hereby deleted and replaced with the following:

The closure date for the purpose of making partial progress payments will be the last d
ay of each month. CONTRACTOR shall prepare the approximate measurement of the work performed through the closure date and submit it to CITY for approval by the tenth (10th) day of the following month. Payments will be withheld pending receipt of any outstanding reports required by the Contract Documents. A full five percent (5%) retention will be deducted from all progress payments. Partial payments on the Contract price shall not be considered as an acceptance of any part of the work.

Upon completion of the work, CONTRACTOR shall so notify the Project Manager, in writing, submit satisfactory evidence of payment for equipment, materials and labor, submit "CONTRACTOR'S AFFIDAVIT." Upon receipt of the notification, the Project Manager shall promptly, by personal inspection, determine the actual status of the work in accordance with the terms of the Contract. If he finds materials, equipment, or workmanship that do not meet the terms of the Contract, he shall prepare a preliminary punch list of such items and submit it to CONTRACTOR. Final determination of acceptability shall be made by CITY. Upon acceptance of the work, CITY shall file a Notice of Completion. The conditions of the guarantee shall commence on the date that CITY files a Notice of Completion. CITY shall make final payment to CONTRACTOR in the manner provided by law following the expiration of thirty-five (35) days after filing the Notice of Completion.

The final payment shall include the entire sum found to be due hereunder after deducting all previous payments and such other lawful amounts as the terms of this Contract describe.

7. LI QUIDATED DAMAGES; EXTENSION OF TIME. In accordance with Government Code Section 53069.85, CONTRACTOR agrees to forfeit and pay to CITY the sum of five hundred dollars ($500) per day for each calendar day completion is delayed beyond the time allowed pursuant to paragraph 4 of this Contract.

Such sum shall be deducted from any payments due to or to become due to CONTRACTOR. CONTRACTOR will be granted an extension of time and will not be assessed liquidated damages for unforeseeable delays beyond the control of and without the fault or negligence of CONTRACTOR, including delays caused by CITY.

CONTRACTOR is required to promptly notify CITY of any such delay.

8. WAIVER OF C LAIMS. Unless a shorter time is specified elsewhere in this Contract, on or before making final request for payment under paragraph 6 above, CONTRACTOR shall submit to CITY, in writing, all claims for compensation under or arising out of this Contract; the acceptance by CONTRACTOR of the final payment shall constitute a waiver of all claims against CITY under or arising out of this Contract except those previously made in writing and request for payment. CONTRACTOR shall be required to execute an affidavit, release, and indemnify agreement with each claim for payment.

CITY OF MURRIETA, COMMUNITY SERVICES DEPARTMENT
01375.0001/977105.1 CONTRACT C 4 CITY PROJECT 23-472, TOT LOT REPLACEMENT PROJECT PHASE 2

9. PREVAILING WAGES. Pursuant to provisions of Section 1773 of the Labor Code of the State of California, the City Council has obtained the general prevailing rate of per diem wages and the general rate for holiday and overtime work in this locality for each craft, classification, or type of workman needed to execute this Contract, from Director of the Department of Industrial Relations. These rates are on file with the City Clerk.

Copies may be obtained at cost at the City Clerk's office of Murrieta. CONTRACTOR shall post a copy of such rates at the job site and shall pay the adopted prevailing wage rates as a minimum. CONTRACTOR shall comply with the provisions of Sections 1773.8, 1775, 1776, 1777.5, 1777.6, and 1813 of the Labor Code.

P
ursuant to the provisions of 1775 of the Labor Code, CONTRACTOR shall forfeit to CITY, as a penalty, the sum of fifty dollars ($50.00) for each calendar day, or portion thereof, for each laborer, worker, or mechanic employed, paid less than the stipulated prevailing rates for any work done under this Contract, by him or by any subcontractor under him, in violation of the provisions of the Contract.

10. W ORKERS' COMPENSATION LIABILITY INSURANCE . CONTRACTOR, by executing this Agreement, hereby certifies:
"I am aware of the provision of Section 3700 of the Labor Code that requires every e
mployer to be insured against liability for Workers' Compensation or undertake self- insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the work of this Contract."

11. T IME OF THE ESSENCE. Time is of the essence in this Contract.

12. INDEMNIFICATION. All work covered by this Contract done at the site of construction or in preparing or delivering materials to the site shall be at the risk of CONTRACTOR alone. CONTRACTOR agrees to save, indemnify, hold harmless, and defend CITY, its officers, employees, and agents against any and all liability, injuries, or death of persons (CONTRACTOR's employees included) and damage to property, arising directly or indirectly out of the obligations herein undertaken or out of the operations conducted by CONTRACTOR, save and except claims or litigations arising through the sole active negligence or sole willful misconduct of CITY.

13. CONTRACTOR'S INDEPENDENT INVESTIGATION. N o plea of ignorance of conditions that exist or that may hereafter exist or of conditions of difficulties that may be encountered in the execution of the work under this Contract, as a result of failure to make the necessary independent examinations and investigations, and no plea of reliance on initial investigations or reports prepared by CITY for purposes of letting this Contract out to bid will be accepted as an excuse for any failure or omission on the part of CONTRACTOR to fulfill in every detail all requirements of this Contract. Nor will such reasons be accepted as a basis for any claims whatsoever for extra compensation or for an extension of time.

CITY OF MURRIETA, COMMUNITY SERVICES DEPARTMENT
01375.0001/977105.1 CONTRACT C 5 CITY PROJECT 23-472, TOT LOT REPLACEMENT PROJECT PHASE 2

14. GRATUITIES. CONTRACTOR warrants that neither it nor any of its employees, agents, or representatives has offered or given any gratuities or promises to CITY's employees, agents, or representatives with a view toward securing this Contract or securing favorable treatment with respect thereto.

15. C ONFLICT OF INTEREST . CONTRACTOR warrants that he has no blood or marriage relationship, and that he is not in any way associated with any City officer or employee, or any architect, engineer, or other preparer of the Drawings and Specifications for this project.

CONTRACTOR further warrants that no person in his employ has been employed by CITY within one (1) year of the date of Notice Inviting Bids.

16. CONTRACTOR'S AFFIDAVIT. A fter completion of the work contemplated by this Contract, CONTRACTOR shall file with the City Manager his affidavit stating that all workmen and persons employed, all firms supplying materials, and all subcontractors upon the project have been paid in full, and that there are no claims outstanding against the project for either labor or materials, except certain items, if any, to be set forth in an affidavit covering disputed claims or items in connection with a Stop Notice that has been filed under the provisions of the laws of the State of California.

17. S IGNATURE OF CONTRACTOR

Corporations:

The signature must contain the name of the corporation, must be signed by the President and Secretary or Assistant Secretary, and the corporate seal must be affixed. Other persons may sign for the corporation in lieu of the above if a certified copy of a resolution of the corporate board of directors so authorizing them to do so is on file in the City Clerk's office.

Partnerships:

Names of all persons comprising the partnership or co-partnership must be stated. Bid must be signed by all partners comprising the partnership unless proof in the form of a certified copy of a certificate of partnership acknowledging signer to be a general partner is presented to the City Clerk, in which case the general partner may sign.

Joint V entures :

Bids submitted as joint ventures must so state and be signed by each joint venturer.

Individuals:

Bids submitted by individuals must be signed by the bidder, unless an up-to-date power of attorney is on file in the City Clerk's office, in which case said person may sign for the individual.

The above rules also apply in the case of the use of a fictitious firm name. In addition, however, where the fictitious name is used, it must be so indicated in the signature.

CITY OF MURRIETA, COMMUNITY SERVICES DEPARTMENT
01375.0001/977105.1 CONTRACT C 6 CITY PROJECT 23-472, TOT LOT REPLACEMENT PROJECT PHASE 2

18. SUBSTITUTED SECURITY. In accordance with Section 22300 of the Public Contracts Code, CONTRACTOR may substitute securities for any monies withheld by CITY to ensure performance under the Contract.

A
t the request and expense of CONTRACTOR, securities equivalent to the amount withheld shall be deposited with CITY or with a State or Federally chartered bank or an escrow agent who shall pay such monies to CONTRACTOR upon notification by CITY of CONTRACTOR's satisfactory completion of the Contract. The type of securities deposited and the method of release shall be approved by the City Attorney's office.

19. R ESOLUTION OF CLAIMS . In the event of any dispute or controversy with the City over any matter whatsoever, the Contractor shall not cause any delay or cessation in or of work, but shall proceed with the performance of the work in dispute. The Contractor shall retain any and all rights provided that pertain to the resolution of disputes and protests between the Parties. The disputed work will be categorized as an “unresolved dispute” and payment, if any, shall be as later determined as set forth below. The Contractor shall keep accurate, detailed records of all disputed work, claims and other disputed matters.

Section 20104 et seq. of the California Public Contract Code prescribes a process ut
ilizing informal conferences, non- binding judicial -supervised mediation, and judicial arbitration to resolve disputes on construction claims of $375,000 or less.

Section 9204 of the Public Contract Code prescribes a process for negotiation and mediation to resolve disputes on construction claims. The intent of this Section is to implement Sections 20104 et seq. and Section 9204 of the California Public Contract Code. This Section shall be construed to be consistent with said statutes.

For purposes of these procedures, “claim” means a separate demand by the Contractor, after the City has denied Contractor’s timely and duly made request for payment for extra work and/or a time extension, for (A) a time extension, (B) payment of money or damages arising from work done by or on behalf of the Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or the Contractor is not otherwise entitled to, or (C) an amount the payment of which is disputed by the City.

The following requirements apply to all claims to which this section applies:
(a) Claim Submittal. The claim shall be in writing and include the documents necessary to substantiate the claim. Claims governed by this procedure must be filed on or before the date of final payment. Nothing in this section is intended to extend the time limit or supersede notice requirements otherwise provided in the Contract for the filing of claims, including all requirements pertaining to compensation or payment for extra work, disputed work, and/or changed conditions. Failure to follow such contractual requirements shall bar any claims or subsequent lawsuits for compensation or payment thereon.
(b) Supporting Documentation. The Contractor shall submit all claims in the following format:
(i) Summary of the claim, including references to the specific Contract Document provisions upon which the claim is based.

CITY OF MURRIETA, COMMUNITY SERVICES DEPARTMENT
01375.0001/977105.1 CONTRACT C 7 CITY PROJECT 23-472, TOT LOT REPLACEMENT PROJECT PHASE 2

(ii) List of documents relating to claim: (a) Specifications, (b) Drawings, (c) Clarifications (Requests for Information), (d) Schedules, and (e) Other. (iii) Chronology of events and correspondence related to the claim. (iv) Statement of grounds for the claim.
(v) Analysis of the claim’s cost, if any.
(vi) Analysis of the claim’s time/schedule impact, if any. (c) City’s Response. Upon receipt of a claim pursuant to this section, City shall conduct a reasonable review of the claim and, within a period not to exceed 45 calendar days, shall provide the Contractor a written statement identifying what portion of the claim is disputed and what portion is undisputed. Any payment due on an undisputed portion of the claim will be processed and made within 60 calendar days after the City issues its written statement.
(i) If the City needs approval from the City Council to provide the Contractor a written statement identifying the disputed portion and the undisputed portion of the claim, and the City Council does not meet within the 45 calendar days or within the mutual ly agreed to extension of time following receipt of a claim sent by registered mail or certified mail, return receipt requested, the City shall have up to three days following the next duly publicly noticed meeting of the City Council after the 45-day period, or extension, expires to provide the Contractor a written statement identifying the disputed portion and the undisputed portion.
(ii) Within 30 calendar days of receipt of a claim, the City may request in writing additional documentation supporting the claim or relating to defenses or claims the City may have against the Contractor. If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual Contract of City and the Contractor.
(iii) The City’s written response to the claim, as further documented, shall be submitted to the Contractor within 30 calendar days (if the claim is less than $50,000, within 15 calendar days) after receipt of the further documentation, or within a period of time no greater than that taken by the Contractor in producing the additional information or requested documentation, whichever is greater. (d) Meet and Confer. If the Contractor disputes the City’s written response, or the City fails to respond within the time prescribed, the Contractor may so notify the City, in writing, either within 15 calendar days of receipt of the City’s response or wit hin 15 calendar days of the City’s failure to respond within the time prescribed, respectively, and demand an informal conference to meet and confer for settlement of the issues in dispute. Upon receipt of a demand, the City shall schedule a meet and confe r conference within 30 calendar days for settlement of the dispute. (e) Mediation. Within 10 business days following the conclusion of the meet and confer conference, if the claim or any portion of the claim remains in dispute, the City shall provide the Contractor a written statement identifying the portion of the claim that remains in dispute and the portion that is undisputed. Any payment due on an undisputed portion of the claim shall be processed and made within 60 calendar days after the City issues its written statement. Any disputed portion of the claim, as

CITY OF MURRIETA, COMMUNITY SERVICES DEPARTMENT
01375.0001/977105.1 CONTRACT C 8 CITY PROJECT 23-472, TOT LOT REPLACEMENT PROJECT PHASE 2

identified by the Contractor in writing, shall be submitted to nonbinding mediation, with the City and the Contractor sharing the associated costs equally. The City and Contractor shall mutually agree to a mediator within 10 business days after the disputed portion of the claim has been identified in writing, unless the Parties agree to select a mediator at a later time.
(i) If the Parties cannot agree upon a mediator, each Party shall select a mediator and those mediators shall select a qualified neutral third Party to mediate with regard to the disputed portion of the claim. Each Party shall bear the fees and costs charged by its respective mediator in connection with the selection of the neutral mediator. (ii) For purposes of this section, mediation includes any nonbinding process, including, but not limited to, neutral evaluation or a dispute review board, in which an independent third party or board assists the Parties in dispute resolution through negotiation or by issuance of an evaluation. Any mediation utilized shall conform to the timeframes in this section.
(iii) Unless otherwise agreed to by the City and the contractor in writing, the mediation conducted pursuant to this section shall excuse any further obligation under Public Contract Code Section 20104.4 to mediate after litigation has been commenced. (iv) All unresolved claims shall be considered jointly in a single mediation, unless a new unrelated claim arises after mediation is completed. (f) City’s Responses. The City’s failure to respond to a claim from the Contractor within the time periods described in this section or to otherwise meet the time requirements of this section shall result in the claim being deemed rejected in its entirety. A claim that is denied by reason of the City’s failure to have responded to a claim, or its failure to otherwise meet the time requirements of this section, shall not constitute an adverse finding with regard to the merits of the claim or the responsibility of qualifications of the Contractor. City’s failure to respond shall not waive City’s rights to any subsequent procedures for the resolution of disputed claims. (g) Government Code Claims. If following the mediation, the claim or any portion remains in dispute, the Contractor must comply with the claim procedures set forth in Government Code section 900 et seq. prior to filing any lawsuit against the City. Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to extra work, disputed work, construction claims, and/or changed conditions, including any required mediation, have been followed by Contractor. If no such Government Code claim is submitted, or if the prerequisite contractual requirements are not satisfied, no action against the City may be filed. A Government Code claim must be filed no earlier than the date that Contractor completes all contractual prerequisites to filing a Government Code claim, including any required mediation. A Government Code claim shall be inclusive of all unresolved claims unless a new unrelated claim arises after the Government Code claim is submitted. For purposes of Government Code section 900 et seq., the running of the period of time within which a claim must be filed shall be tolled from the time the Contractor submits his or her written claim to the City until the time the claim is denied, including any period of time utilized by the meet and confer conference or mediation that does not result in a complete resolutions of all claims.

CITY OF MURRIETA, COMMUNITY SERVICES DEPARTMENT
01375.0001/977105.1 CONTRACT C 9 CITY PROJECT 23-472, TOT LOT REPLACEMENT PROJECT PHASE 2

(h) Civil Actions for Claims of $375,000 or Less. The following procedures are established for all civil actions filed to resolve claims totaling $375,000 or less:
(i) Within 60 calendar days, but no earlier than 30 calendar days, following the filing or responsive pleadings, the court shall submit the matter to non- binding mediation unless waived by mutual stipulation of both Parties or unless mediation was held prior to commencement of the action in accordance with Public Contract Code section 9204 and the procedures in this Section. The mediation process shall provide for the selection within 15 calendar days by both Parties of a disinterested third person as mediator, shall be commenced within 30 calendar days of the submittal, and shall be concluded within 15 calendar days from the commencement of the mediation unless a time requirement is extended upon a good cause showing to the court or by stipulation of both Parties. If the Parties fail to select a mediator within the 15-day period, either Party may petition the court to appoint the mediator.
(ii) If the matter remains in dispute, the case shall be submitted to judicial arbitration pursuant to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, notwithstanding Section 1141.11 of that code. The Civi l Discovery Act (Title 4 (commencing with Section 2016.010) of Part 4 of the Code of Civil Procedure) shall apply to any proceeding brought under this subdivision consistent with the rules pertaining to judicial arbitration. (iii) Upon stipulation of the Parties, arbitrators appointed for these purposes shall be experienced in construction law, and, upon stipulation of the Parties, mediators and arbitrators shall be paid necessary and reasonable hourly rates of pay not to exce ed their customary rate, and such fees and expenses shall be paid equally by the Parties, except in the case of arbitration where the arbitrator, for good cause, determines a different division.
(iv) In addition to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, any Party who after receiving an arbitration award requests a trial de novo but does not obtain a more favorable judgment shall, in addition to payment of costs and fees under that chapter, pay the attorney’s fees of the other Party arising out of the trial de novo.

20. NOT
ICE TO CITY OF LABOR DISPUTES. Whenever CONTRACTOR has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of the Contract, CONTRACTOR shall immediately give notice thereof, including all relevant information with respect thereto, to CITY.

21. BOOKS AND RECORDS. C ONTRACTOR's books, records, and plans or such part thereof as may be engaged in the performance of this Contract, shall at all reasonable times be subject to inspection and audit by any authorized representative of CITY.

22. UTILITY L OCATION. CITY acknowledges its responsibilities with respect to locating utility facilities pursuant to California Government Code Section 4215.

23. REGIONAL NOTIFICATION CENTERS . C ONTRACTOR agrees to contact the appropriate regional notification center in accordance with Government Code Section 4216.2.

24. TRENCH PROTECTION AND EXCAVATION . C ONTRACTOR shall submit its detailed plan for worker protection during the excavation of trenches required by the

CITY OF MURRIETA, COMMUNITY SERVICES DEPARTMENT
01375.0001/977105.1 CONTRACT C 10 CITY PROJECT 23-472, TOT LOT REPLACEMENT PROJECT PHASE 2

scope of the work in accordance with Labor Code Section 6705.

A. CONTRACTOR shall, without disturbing the condition, notify CITY, in writing, as soon as CONTRACTOR, or any of CONTRACTOR's
subcontractors, agents, or employees have knowledge and reporting is possible, of the discovery of any of the following conditions:
(1) The presence of any material that CONTRACTOR believes is hazardous waste, as defined in Section 25117 of the Health and Safety Code;
(2) Subsurface or latent physical conditions at the site differing from those indicated in the specifications; or
(3) Unknown physical conditions at the site of any unusual nature, different materially for those ordinarily encountered and generally recognized as inherent in work of the character provided for in this Contract.

B. Pending a determination by CITY of appropriate action to be taken, CONTRACTOR shall provide security measures (e.g., fences) adequate to prevent the hazardous waste or physical conditions from causing bodily injury to any person.

C. CITY shall promptly investigate the reported conditions. If CITY, through and in the exercise of its sole discretion, determines that the conditions do materially differ or do involve hazardous waste, and will cause a decrease or increase in CONTRACTOR's cost of, or time required for, performance of any part of the work, then CITY shall issue a change order.

D. In the e vent of a dispute between CITY and CONTRACTOR as to whether the conditions materially differ, or involve hazardous waste, or cause a decrease or increase in CONTRACTOR's cost of, or time required for, performance of any part of the work, CONTRACTOR shall not be excused from any scheduled completion date, and shall proceed with all work to be performed under the contract. CONTRACTOR shall retain any and all rights that pertain to the resolution of disputes and protests between the parties.

25. I
NSPECTION. The work shall be subject to inspection and testing by CITY and its authorized representatives during manufacture and construction and all other times and places, including, without limitation, the plans of CONTRACTOR and any of its suppliers. CONTRACTOR shall provide all reasonable facilities and assistance for the safety and convenience of inspectors. All inspections and tests shall be performed in such manner as to not unduly delay the work. The work shall be subject to final inspection and acceptance notwithstanding any payments or other prior inspections. Such final inspection shall be made within a reasonable time after completion of the work.

26. DISCRIMINATION. CO NTRACTOR represents that it has not, and agrees that it will not, discriminate in its employment practices on the basis of race, creed, religion, national origin, color, sex, age, or handicap.

27. GOVERNING LAW . This Contract and any dispute arising hereunder shall be

CITY OF MURRIETA, COMMUNITY SERVICES DEPARTMENT
01375.0001/977105.1 CONTRACT C 11 CITY PROJECT 23-472, TOT LOT REPLACEMENT PROJECT PHASE 2

governed by the law of the State of California.

28. W RITTEN NOTICE. Any written notice required to be given in any part of the Contract Documents shall be performed by depositing the same in the U.S. Mail, postage prepaid, directed to the address of CONTRACTOR as set forth in the Contract Documents, and to CITY addressed as follows:

B
rian Crawford
Senior Program Manager
City of Murrieta
1 Town Square
Murrieta, CA 92562

CITY OF MURRIETA, COMMUNITY SERVICES DEPARTMENT
01375.0001/977105.1 CONTRACT C 12 CITY PROJECT 23-472, TOT LOT REPLACEMENT PROJECT PHASE 2

IN WITNESS WHEREOF, the parties hereto have caused this Contract to be executed on the date first above written.

DATED: R.E. SCHULTZ CONSTRUCTION, INC.

By:

Richard E. Schultz (Sole Officer)

Print or type NAME
President
Print or type TITLE
714-649-2627
Phone Number

By:

Richard E. Schultz (Sole Officer)

Print or type NAME
Secretary
Print or type TITLE
714-649-2627
Phone Number

DATED:

APPROVED AS TO FORM:

Tiffany J. Israel, City Attorney

ATTEST:

Cristal McDonald, City Clerk

CITY OF MURRIETA

By:

Lori Stone, Mayor

SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE

THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS.

INSURER(S) AFFORDING COVERAGE
INSURER F :

INSURER E :

INSURER D :

INSURER C :

INSURER B :

INSURER A :

NAIC #
NAME:

CONTACT
(A/C, No):

FAX
E-MAIL
ADDRESS:

PRODUCER
(A/C, No, Ext):

PHONE

INSURED
REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed.

If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).

THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS

CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.

OTHER:
(Per accident)
(Ea accident)
$
$
N / A
SUBR
WVD
ADDL
INSD

THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS

CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $
$
$
$PROPERTY DAMAGE
BODILY INJURY (Per accident)
BODILY INJURY (Per person)

COMBINED SINGLE LIMIT

AUTOS ONLY

AUTOSAUTOS ONLY

NON-OWNED

SCHEDULEDOWNED

ANY AUTO

AUTOMOBILE LIABILITY
Y / N

WORKERS COMPENSATION

AND EMPLOYERS' LIABILITY
OFFICER/MEMBER EXCLUDED?
(Mandatory in NH)
DESCRIPTION OF OPERATIONS below
If yes, describe under

ANY PROPRIETOR/PARTNER/EXECUTIVE
$
$
$
E.L. DISEASE - POLICY LIMIT
E.L. DISEASE - EA EMPLOYEE
E.L. EACH ACCIDENT
ER
OTH-

STATUTE
PER

LIMITS(MM/DD/YYYY)

POLICY EXP
(MM/DD/YYYY)

POLICY EFF

POLICY NUMBERTYPE OF INSURANCELTR
INSR
DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required)

EXCESS LIAB
UMBRELLA LIAB $EACH OCCURRENCE
$AGGREGATE
$
OCCUR

CLAIMS-MADE
DED RETENTION $
$PRODUCTS - COMP/OP AGG
$GENERAL AGGREGATE
$PERSONAL & ADV INJURY
$MED EXP (Any one person)
$EACH OCCURRENCE

DAMAGE TO RENTED
$PREMISES (Ea occurrence)

COMMERCIAL GENERAL LIABILITY

CLAIMS-MADE OCCUR
GEN'L AGGREGATE LIMIT APPLIES PER:

POLICY PRO-

JECT LOC

CERTIFICATE OF LIABILITY INSURANCE

DATE (MM/DD/YYYY)

CANCELLATION

AUTHORIZED REPRESENTATIVE
ACORD 25 (2016/03)
© 1988-2015 ACORD CORPORATION. All rights reserved.

CERTIFICATE HOLDER
The ACORD name and logo are registered marks of ACORD
HIRED

AUTOS ONLY
04/11/2024
KGIB, INC.

KNOX GENERAL INSURANCE BROKERS
226 SOUTH GLASSELL STREET
ORANGE
CA
92866
Carol Knox, Monica Avelar or Kim Rhodes
(714) 744-3300
(714) 744-6537
[email protected], [email protected], [email protected]
R.E. SCHULTZ CONSTRUCTION, INC
1767 N BATAVIA STREET
ORANGE
CA
92865

SCOTTSDALE INSURANCE COMPANY
41297

CLEAR BLUE SPECIALITY INSURANCE COMPANY
37745
A
X
X
BCS2000828
08/16/2023
08/16/2024
1,000,000
100,000

EXCLUDED
1,000,000
2,000,000
2,000,000
B
BW02-STR-2300180-00
06/19/2023
06/19/2024
1,000,000
A
XLS2002647
08/16/2023
08/16/2024
2,000,000
2,000,000
Over General Liability
& Work Comp
--N/A--
RE: Tot Lot Improvement Project Phase 2 - City Project No. 23-472 - CIP 22029, 22030, 22031, 22032, and 22040 City of Murrieta, its officers, officials, employees, and volunteers are named as additional insured per form CG2010 12 19, ongoing operations and per form CG2037 12 19, Completed operations, Primary and Non-Contributory wording per form CG2001 12 19 and waiver of subrogation per form CG2404 12 19 with respect to General Liability as required by written contract. Excess Liability Policies follow underlying General Liability, Auto Liability.

City of Murrieta
Community Service Department
1 Town Square
Murrieta
CA
92562
POLICY NUMBER: BCS2000828 COMMERCIAL GENERAL LIABILITY
CG 20 10 12 19
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.

CG 20 10 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 2 ADDITIONAL INSURED – OWNERS, LESSEES OR
CONTRACTORS – SCHEDULED PERSON OR

ORGANIZATION
This endorsement modifies insurance provided under the following:

COMMERCIAL GENERAL LIABILITY COVERAGE PART

SCHEDULE
Name Of Additional Insured Person(s)
Or Organization(s) Location(s) Of Covered Operations

ANY PERSON OR ORGANIZATION WHEN

REQUIRED BY WRITTEN CONTRACT OR

AGREEMENT, EXECUTED PRIOR TO THE

OCCURRENCE TO WHICH THIS INSURANCE

APPLIES, THAT SUCH PERSON OR

ORGANIZATION BE ADDED AS AN
ADDITIONAL INSURED ON YOUR POLICY.

ALL LOCATIONS
Information required to complete this Schedule, if not shown above, will be shown in the Declarations.

1. Your acts or omissions; or

2. The acts or omissions of those acting on your
behalf;
in the performance of your ongoing operations fo r
the additional insured(s) at the location(s)
designated above.

However:

1. The insurance afforded to such additional
insured only applies to the extent permitted by
law; and

2. If coverage provided to the additional insured is
required by a contract o r agreement, the
insurance afforded to such additional insured
will not be broader than that which you are
required by the contract or agreement to provide
for such additional insured.

B. With respect to the insurance afforded to these
additional insured s, the following additional
exclusions apply:

This insurance does not apply to "bodily injury" or
"property damage" occurring after:

1. All work, including materials, parts or equipment
furnished in connection with such work, on the
project (other than se rvice, maintenance or
repairs) to be performed by or on behalf of the
additional insured(s) at the location of the
covered operations has been completed; or

2. That portion of "your work" out of which the
injury or damage arises has been put to its
intended use by any person or organization
other than another contractor or subcontractor
engaged in performing operations for a principal
as a part of the same project.

Page 2 of 2 ends

C. With respect to the insurance afforded to these
additional insureds, the following is added to
Section III – Limits Of Insurance:

If coverage provided to the additional insured is
required by a contract or agreement, the most we
will pay on behalf of the additional insured is the
amount of insurance:

1. Required by the contract or agreement; or

2. Available under the applicable limits of
insurance;
whichever is less.

This endorsement shall not increase the applicable
limits of insurance.

COMMERCIAL GENERAL LIABILITY

POLICY NUMBER: BCS2000828
CG 20 37 12 19
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.

CG 20 37 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 ADDITIONAL INSURED – OWNERS, LESSEES OR
CONTRACTORS – COMPLETED OPERATIONS
Thi
s endorsement modifies insurance provided under the following:

COMMERCIAL GENERAL LIABILITY COVERAGE PART

PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART
SCH
EDULE
Name Of Additional Insured Person(s)
Or Organization(s) Location And Description Of Completed Operations Any person or organization when
required by written contract or
agreement, executed prior to the
occurrence to which this insurance
applies, that such person or
organization be added as an
additional insured on your policy
All Locations
Information required to complete this Schedule, if not shown above, will be shown in the Declarations.

A. Se
ction II – Who Is An Insured is amended to
include as an additional insured the person(s) or
organization(s) shown in the Schedule, but only
with respect to liability for "bodily injury" or
"property damage" caused, in whole or in part, by
"your work" at the location designated and
described in the S chedule of this endorsement
performed for that additional i nsured and included
in the "products-completed operations hazard".

However:

1. The insurance afforded to such additional
insured only applies to the extent permitted by
law; and

2. If coverage provided to the additional insured is
required by a contract or agreement, the
insurance afforded to such additional insured
will not be broader than that which you are
required by the contract or agreement to
provide for such additional insured.

B. With respect to the insurance afforded to these
additional insureds, the following is added to
Section III – Limits Of Insurance:

If coverage provided to the additional insured is
required by a contract or agreement, the most we
will pay on behalf of the additional insured is the
amount of insurance:

1. Required by the contract or agreement; or

2. Available under the applicable limits of
insurance;
whichever is less.

This endorsement shall not increase the
applicable limits of insurance.

COMMERCIAL GENERAL LIABILITY
CG 20 01 12 19
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.

OTHER INSURANCE CONDITION
This endorsement modifies insurance provided under the following:

COMMERCIAL GENERAL LIABILITY COVERAGE PART

LIQUOR LIABILITY COVERAGE PART

PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART
The following is added to the Other Insurance
Condition and supersedes any provision to the
contrary:

Primary And Noncontributory Insurance
This insurance is primary to and will not seek
contribution from any other insurance available to
an additional insured under your policy provided
that:
(1) The additional insured is a Named Insured
under such other insurance; and
(2) You have agreed in wr iting in a contract or
agreement that this insurance would be
primary and would not seek contribution
from any other insurance available to the
additional insured.

POLICY NUMBER: BCS2000828
POLICY NUMBER: BCS2000828 COMMERCIAL GENERAL LIABILITY
CG 24 04 12 19
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.

WAIVER OF TRANSFER OF RIGHTS OF RECOVERY

AGAINST OTHERS TO US (WAIVER OF SUBROGATION)
This
endorsement modifies insurance provided under the following:

COMMERCIAL GENERAL LIABILITY COVERAGE PART

ELECTRONIC DATA LIABILITY COVERAGE PART

LIQUOR LIABILITY COVERAGE PART

POLLUTION LIABILITY COVERAGE PART DESIGNATED SITES

POLLUTION LIABILITY LIMITED COVERAGE PART DESIGNATED SITES

PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART

RAILROAD PROTECTIVE LIABILITY COVERAGE PART

UNDERGROUND STORAGE TANK POLICY DESIGNATED TANKS
SCHE
DULE
Name Of Person(s) Or Organization(s):

Any person or organization for whom the insured has agreed to waive rights of recovery, provided such agreement is made in writing and prior to the loss
Information required to complete this Schedule, if not shown above, will be shown in the Declarations.

The fol
lowing is added to Paragraph 8. Transf er Of
Rights Of Recovery Against Oth ers To Us of
Section IV – Conditions:

We waive any right of recovery against the person(s)
or organi zation(s) shown in the Schedule above
because of pay ments we make under this Coverage
Part. Such waiver by us applies only to the extent that the insured has waived its right of recovery against
such person(s) or organization(s) prior to loss. This
endorsement applies only to the person(s) or
organization(s) shown in the Schedule above.

ANY PROPRIETOR/PARTNER/EXECUTIVE
OFFICER/MEMBER EXCLUDED?

ADDL SUBRINSR

LTR INSD WVD

DATE (MM/DD/YYYY)
CONTACTPR ODUCER NAME:

FAXPH ONE
(A/C, No):(A/C, No, Ext):

E-M AIL
ADDRESS:

INSU RER A :

INSU RED INSU RER B :

INSU RER C :

INSU RER D :

INSU RER E :

INSU RER F :

POLICY EFF POLICY EXPTYPE OF INSU RANCE LIMITSPOLICY NUMBER (MM/DD/YYYY) (MM/DD/YYYY)

AUTOMOBILE LIABILITY

UMBRELLA LIAB

EXC ESS LIAB

WORKER S COMPEN SAT ION

AND EM PLOYER S' LIABILITY
DESC RIPTION OF OPER ATIONS / LOCATIONS / VEH ICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required)

AUTHORIZED REPR ESEN TATIVE
EACH OCCURRENCE $
DAMAGE TO RENTEDCLAIMS-MADE OCCUR $PREMISES (Ea occurrence) MED EXP (Any one person) $
PERSONAL & ADV INJURY $
GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $
PRO-POLICY LOC PRODUCTS - COMP/OP AGG $JECT
$OTHER:

COMBINED SINGLE LIMIT $(Ea accident)
ANY AUTO BODILY INJURY (Per person) $
OWNED SCHEDULED BODILY INJURY (Per accident) $AUTOS ONLY AUTOS HIRED NON-OWNED PROPERTY DAMAGE $(Per accident)AUTOS ONLY AUTOS ONLY $
EACH OCCURRENCE $OCCUR
CLAIMS-MADE AGGREGATE $
$DED RETENTION $

PER OTH-

STATUTE ER
E.L. EACH ACCIDENT $
E.L. DISEASE - EA EMPLOYEE $
If yes, describe under
E.L. DISEASE - POLICY LIMIT $DESCRIPTION OF OPERATIONS below INSURER(S) AFFORDING COVERAGE NAIC #

COMMERCIAL GENERAL LIABILITY
Y / N
N / A
(Mandatory in NH)

SHOULD ANY OF THE ABOVE DESC RIBED POLICIES BE CANCELLED BEFORE

THE EXPI RATION DATE THEREOF, NOTICE WILL BE DELIVER ED IN ACCORDANCE WITH THE POLICY PROVISIONS.

THIS CERTIFICATE IS ISSU ED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS

CERTIFICATE DOES NOT AFFIRMATIVEL Y OR NEGATIVEL Y AMEN D, EXT END OR ALTER THE COVER AGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSU ING INSURER(S), AUTHORIZED REPR ESEN TATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.

IMPO RTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed.

If SUBROGATION IS WAIVED , subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).

COVERAGES CERTIFICATE NUMBER: REVISION NUMBER:

The ACORD name and logo are registered marks of ACORDACORD 25 (2016/03)

CERTIFICATE OF LIABILITY INSURANCE
Policy Number:
1767 N. Batavia St
Orange, CA 92865
The Hulett Agency
13959 Saddlewood Drive
Poway, CA 92064
(858)618-5442
Date Entered:
(858)618-5444
[email protected]
R E Schultz Construction, Inc.
04/09/2024
A WSD5065120-02 04/14/2024 04/14/2025 1,000,000
1,000,000
1,000,000
Project Name/Location:Tot Lot Improvement Project Phase 2,City Project No. 23-472 City of Murrieta
1 Town Square
Murrieta, CA 92562
CIP 22029, 22030, 22031, 22032, and 22040
Waiver of Subrogation attached
27847
4/11/2023
n
Insurance Company of the West

WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 99 06 34

(Ed. 8-00)

WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT - BLANKET

We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us).

The additional premium for this endorsement shall be 2% of the total California Workers’ Compensation premium otherwise due.

Schedule

Person or Organization Job Description

ANY PERSON OR ALL CALIFORNIA ALL CALIFORNIA OPERATIONS
ORGANIZATION FOR OPERATIONS.

WHICH THIS WAIVER
IS REQUIRED.

Policy Number: WSD 5065120-02 Insured: R E Schultz Construction Inc

Endorsement Effective: 4/14/2024 Coverage Provided by: Ins Co of the West

Issue Date: 04/10/2024 Countersigned by:

WC 99 06 34
(Ed. 8-00)

Murrieta City CouncilMay 20, 2025

Murrieta City Council
May 20, 2025