AGREEMENT FOR ON-CALL PROFESSIONAL SERVICES WITH THE CITY OF MURRIETA ("CITY") Project Name/Description ("Project"): On-Call Vertical Construction/Project Management Services Contract Number: Click or tap here to enter text. Consultant Name ("Consultant"): Griffin Structures Consultant Business Type: Corporation Consultant Address:1 Technology Drive, Bldg. Suite #829, Irvine, CA 92618 Consultant Representative Name and Title ("Consultant Representative"): Jon Hughes, President Consultant Representative Work [email protected] Termination Date:06/01/2027
Phone and Email: 949-497-9000 x208,
Total Not-To-Exceed Contract Amount ("Contract Sum"): Each Project will have a Project Specific Quote in compliance with the fees outlined in Exhibit C-1.
City Department Contact ("Department Contact"): Bryce Wilson Department Contact Work Phone and Email: 951-461-6429, [email protected] Is Federal Funding Being Used to Fund Any Part of The Project (Yes/No):No
RECITALS
The City desires to contract with a Consultant to provide professional services on an on call basis as more further set forth herein.
The City circulated a Request for Proposals for the above-described professional services.
Consultant submitted a proposal to City to provide the above-described professional services.
City Staff has reviewed all the proposals and after considering the demonstrated competence of Consultant, the professional qualifications of Consultant, and the fairness and reasonableness of Consultant's proposed cost, staff has determined that an agreement to provide the required services should be awarded to Consultant.
AGREEMENT FOR PROFESSIONAL SERVICES WITH THE CITY OF MURRIETA ("CITY") THIS AGREEMENT FOR SERVICES ("Agreement") is made and entered into as of the effective on the date executed by the City by and between CITY OF MURRIETA, a California municipal corporation ("City") and ("Consultant"). City and Consultant may be referred to individually as "Party" or collectively as "Parties." In consideration of the mutual promises and covenants made by the Parties and contained herein and other consideration, the value and adequacy of which are hereby acknowledged, the Parties agree as follows:
ARTICLE 1. SERVICES OF CONSULTANT
Scope of Services. In compliance with all terms and conditions of this Agreement, Consultant shall provide those services specified in the "Scope of Services" attached hereto as Exhibit A and incorporated herein by this reference, which may be referred to herein as the "services" or "work" hereunder. As a material inducement to City entering into this Agreement, Consultant represents and warrants: a) it has the qualifications, experience, and facilities necessary to properly perform the Services required under this Agreement b) all services set forth in the Scope of Services will be performed in a competent and satisfactory manner; c) all materials used for services will be both of good quality as well as fit for the purpose intended; and, d) Consultant shall follow the highest professional standards and practices in performing the services required hereunder. Individual tasks under the Scope of Services shall be established on a per project basis. Upon request by City, the Consultant shall provide a detailed task proposal including pricing consistent with those hourly rates as provided in Article II, below. Consultant shall not commence work until an Task Order is issued by the City authorizing the Consultant to perform such work.
Consultant's Proposal. The Scope of Services shall include the scope of services or work included in Consultant's proposal or bid, which shall be incorporated herein by this reference as though fully set forth herein. In the event of any inconsistency between the terms of such proposal or bid, and this Agreement, the terms of this Agreement shall govern. No other terms and conditions from Consultant's proposal or bid, other than description of scope of services or work, shall apply to this Agreement, unless specifically agreed to by City in writing.
Compliance with Law. All services rendered hereunder shall be provided in accordance with all ordinances, resolutions, statutes, rules and regulations of City and any federal, State or local governmental agency having jurisdiction in effect at the time services are rendered. City, and its officers, employees and agents, shall not be liable at law or in equity for failure of Consultant to comply with this Section.
Licenses, Permits, Fees and Assessments. Consultant shall obtain at its sole cost and expense such licenses, permits and approvals as may be required by law for the performance of the services required by this Agreement. Consultant shall have the sole obligation to pay for any fees, assessments and taxes, plus applicable penalties and interest, which may be imposed by law and arise from or are necessary for Consultant's performance of the services required by this Agreement, and shall indemnify, defend and hold harmless City against any such fees, assessments, taxes, penalties or interest levied, assessed or imposed against City hereunder.
Familiarity with Work. By executing this Agreement, Consultant represents and warrants Consultant: a) has thoroughly investigated and considered services to be performed, b) has carefully considered how services should be performed, and c) fully understands the facilities, difficulties and restrictions attending performance of services under this Agreement.
Software and Computer Services. If the Scope of Services includes the provision and/or installation of any software, computer system, or other computer technology, Consultant represents ,mci warrants that it is familiar with and/or has inspected City's current infrastructure, equipment, computer system and software and that the software, computer system, or other computer technology provided and/or installed by Consultant under this Agreement is compatible, and shall be fully functional, with such infrastructure, equipment, computer system and software of City. Consuitant acknowiedges that City is relying on this representation by Consultant as a material consideration in entering into this Agreement.
Prevailing Wages. lf services inciude any "pubiic work" or "maintenance work," as those terms are defined in California Labor Code section 1720 et seq. and California Code of Regulations, Title 8, section 16000 et seq., and if the total compensation is $1,000 or more, Consultant shall pay prevailing wages for such work and comply with the requirements in California Labor Code section 1770 et seq. and 1810 et seq., and all other applicable laws.
Special Requirements. Additional terms and conditions of this Agreement, if any, which are made a part hereof are set forth in the "Special Requirements" attached hereto as Exhibit B and incorporated herein by this reference. In the event of a conflict between the provisions of Exhibit B and any other provisions of this Agreement, the provisions of Exhibit B shall govern.
ARTICLE 2. COMPENSATION AND METHOD OF PAYMENT
Contract Sum. Subject to any limitations set forth in this Agreement, City agrees to pay Consultant the rates specified in the "Schedule of Compensation" attached hereto as Exhibit C and incorporated herein by this reference. The total compensation for all work, including reimbursement for actual expenses, shall not exceed the Contract Sum set forth above. Compensation may include reimbursement, for actual and necessary expenditures, if both are specified in the Schedule of Compensation or upon a Task Order, as well as approved by City in advance.
Invoices. Unless some other method of payment is specified in Exhibit C, Schedule of Compensation, in any month in which Consultant wishes to receive payment, no later than the first business day of such month, Consultant shall submit to City, in a form approved by City's Finance Director, an invoice for services rendered prior to the date of the invoice. By submitting an invoice for payment under this Agreement, Consultant is certifying compliance with all provisions of this Agreement. Except as provided in Sections 7.3, 7.4 and 7.5, City shall pay Consultant for all expenses stated thereon which are approved by City pursuant to this Agreement generally within thirty (30) days, and City will use its best efforts to make payment no later than forty-five (45) days, from the submission of an invoice in an approved form. In the event any charges or expenses are disputed by City, the original invoice shall be returned by City to Consultant for correction and resubmission. Review and payment by City for any invoice provided by Consultant shall not constitute a waiver of any rights or remedies provided herein or any applicable law. Each invoice is to include (unless otherwise specified by City): 1) line items for all personnel describing the work performed, the number of hours worked, and the hourly rate; 2) line items for all materials and equipment properly charged to the Services; 3) line items for all other approved reimbursable expenses claimed, with supporting documentation; and 4) line items for all approved subcontractor labor, supplies, equipment, materials, and travel properly charged to the Services.
ARTICLK 3. PERFORMANCE SCHEDULE
Time of Essence. Time is of the essence in the performance of this Agreement.
Term. The Agreement shall commence and become effective on the date excuted by the City and will continue until the Termination Date, June 30, 2027. This Agreement may be extended for up to two, additional one-year periods upon the mutual agreement in writing of both parties.
Unless earlier terminated in accordance with Article 7 of this Agreement, this Agreement shall continue in full force and effect until completion of any ongoing services, which shall be no later than the Termination Date set forth above. Notwithstanding the foregoing, the Indemnification and Insurance provisions set forth in Article 5 shall survive the termination of this Agreement.
Schedule of Performance. Consultant shall commence the services pursuant to this Agreement upon receipt of a written Task Order and shall perform all services within the time period(s) established in the Task Order or generally within the time periods established in the "Schedule of Performance" attached hereto as Exhibit D and incorporated herein by this reference.
Force Majeure. The time period(s) specified in the Schedule of Performance for performance of the services rendered pursuant to this Agreement shall be extended because of any delays due to unforeseeable causes beyond the control and without the fault or negligence of Consultant, including, but not restricted to, acts of God or of the public enemy, unusually severe weather, fires, earthquakes, floods, epidemics, quarantine restrictions, riots, strikes, freight embargoes, wars, litigation, ancf/or acts of any governmental agency, including City, if Consultant shall within ten (10) days of the commencement of such delay notify City in writing of the causes of the delay. City shall ascertain the facts and the extent of delay, and extend the time for performing the services for the period of the enforced delay when and if in the judgment of City such delay is justified. City's determination shall be final and conclusive upon the Parties to this Agreement. In no event shall Consultant be entitled to recover damages against City for any delay in the performance of this Agreement, however caused, Consultant's sole remedy being extension of this Agreement pursuant to this Section.
ARTICLE 4. COORDINATION OF WORK
Representative of Consultant. The Consultant Representative is authorized to act on Consultant's behalf with respect to the work or services specified herein and to make all decisions in connection therewith. It is expressly understood that the experience, knowledge, capability and reputatiop of the representative was a substantial inducement for City to enter into this Agreement. Therefore, the representative shall be responsible during the term of this Agreement for directing all activities of Consultant and devoting sufficient time to personally supervise the services hereunder. For purposes of this Agreement, the representative may not be replaced nor may their responsibilities be substantially reduced by Consultant without the express written approval of City.
Department Contact for City. The Department Contact (or other person designated by the City Manager) shall be the primary person on behalf of City responsible for the administration of the Agreement. It shall be Consultant's responsibility to assure that the Department Contact is kept informed of both the progress of the performance of the services as well as any decisions which must be made by City.
Approvals from City. City approvals or actions, pursuant to the authority of this Agreement, are to be made (unless otherwise specified) either by the Contract Manager, City Manager or by their delegate as provided for in writing.
Independent Contractor. Neither City, nor any of its officers, employees or agents, shall have any control over the manner or means by which Consultant, or its officers, employees, agents or subcontractors, perform the services required herein, except as otherwise set forth herein. Consultant shall perform all services required herein as an independent contractor of City and shall remain under only such obligations as are consistent with that role. Consultant shall not at any time or in any manner represent that it, or any of its officers, employees, agents or subcontractors, are officers, employees or agents of City. City shall not in any way or for any purpose become or be deemed to be a partner of Consultant in its business or otherwise or a joint venturer or a member of any joint enterprise with Consultant. Consultant shall not incur or have the power to incur any debt, obligation or liability whatever against City, or bind City in any manner. Consultant represents and warrants that the personnel used to provide services to City pursuant to this Agreement shall at all times be under Consultant's exclusive control and direction. No City employee benefits shall be available to Consultant, its officers, employees, agents or subcontractors, in connection with the performance of this Agreement.
City shall not be liable for compensation or indemnification to Consultant, its officers, employees, agents or subcontractors, for injury or sickness arising out of performing services hereunder. In the event that Consultant or any officer, employee, agent, or subcontractor of Consultant providing services under this Agreement claims or is determined by a federal or state agency, a court of competent jurisdiction, or the California Public Employees' Retirement System, to be classified as other than an independent contractor for City, then Consultant shall indemnify, defend, and hold harmless City for the payment of any and all assessed fines, penalties, judgments, employee and/or employer contributions, and any other damages and costs assessed to City as a consequence of, or in any way attributable to, the assertion that Consultant, or any officer, employee, agent, or subcontractor Consultant used to provide services under this Agreement, is/are employees of City.
Subcontracting or Assignment. The experience, knowledge, capability and reputation of Consultant, its principals and employees were a substantial inducement for City to enter into this Agreement. Therefore, without express written approval of City, Consultant shall not contract with any other City to perform in whole or in part services required hereunder without express written approval of City, and neither this Agreement nor any interest herein may be transferred or assigned. No approved transfer shall release Consultant, or any surety or insured of Consultant, of any liability hereunder without express written consent of City.
ARTICLE 5. INSURANCE AND INDEMNIFICATION
Insurance Coverages. Prior to commencement of any services under this Agreement, and without limiting Consultant's indemnification obligation to City, Consultant shall procure and maintain, at its sole cost and expense, in a form and content satisfactory to City, for the duration of the Agreement, primary policies of insurance of the type and amounts set forth in the "Insurance Requirements" attached hereto as Exhibit E and incorporated herein by this reference.
Indemnification.
General Obligations. Consultant agrees, to the full extent permitted by law, to indemnify, defend and hold harmless City and its elected and appointed officers, employees and agents (each an "lndemnitee" and collectively, "lndemnitees") against, and will hold and save them and each of them harmless from, whether actual or threatened, any and all actions, either judicial, administrative, arbitration or regulatory claims, damages to persons or property, losses, costs, penalties, obligations, errors, omissions or liabilities (herein "Claims or Liabilities") that may be asserted or claimed by any person, firm or City arising out of or in connection with the negligent performance of the work, operations or activities provided herein of Consultant, its officers, employees, agents, subcontractors, or invitees, or any individual or City for which Consultant is legally liable (each an "Indemnitor" and collectively, "lndemnitors"), or arising from Indemnitors' reckless or willful misconduct, or arising from Indemnitors' negligent performance of or failure to perform any term, provision, covenant or condition of this Agreement, and in connection therewith: 1) Consultant will defend any action or actions filed or threatened in connection with any such Claims or Liabilities, or at option oflndemnitee(s) will reimburse and pay for all costs and expenses, including legal costs and attorneys' fees, incurred by Indemnitee(s) in connection therewith; and, 2) Consultant will promptly pay any judgment rendered against Indemnitee(s) for any such Claims or Liabilities, and will save and hold Indemnitee(s) harmless therefrom.
Further Provisions. The indemnity obligation herein shall be binding on successors, assigns and heirs of Consultant and shall survive termination of this Agreement. Consultant shall incorporate similar indemnity agreements as provided herein with its subcontractors, and if Consultant fails to do so Consultant shall be fully responsible to indemnify City hereunder therefor. Failure of City and/or City Parties (collectively "City" for solely this Section 5.2(b)) to monitor compliance with any of the indemnification provisions herein shall not be a waiver hereof. The indemnification provisions herein do not apply to claims or liabilities occurring as a result of City's sole negligence or willful misconduct, but, to the fullest extent permitted by law, shall apply to claims and liabilities resulting in part from City's negligence, except that design professionals' indemnity hereunder shall be limited to claims and liabilities arising out of the negiigence, recklessness or willful misconduct of the design professional. The indemnification provided herein includes Claims or Liabilities arising from any negligent or wrongful act, error or omission, or reckless or willful misconduct of Indemnitors in the performance of professional services hereunder. Payment of invoices by City is not a condition precedent to enforcement of the indemnity obligation herein. In the event of any dispute between Consultant and City, as to whether liability arises from the sole negligence or willful misconduct of City, Consultant will be obligated to pay for City's defense until such time as a final judgment has been entered adjudicating City as solely negligent or responsible for willful misconduct. Consultant will not be entitled in the absence of such a determination to any reimbursement of defense costs including but not limited to attorney's fees, expert fees and costs oflitigation.
Pursuant to the full language of California Civil Code §2782, Design Professionals agrees to indemnify, including the cost to defend, City and its officers, officials, employees, and volunteers from and against any and all claims, demands, costs, or liability that arise out of, or pertain to, or relate to the negligence, recklessness, or willful misconduct of Design Professional and its employees or agents in the performance of services under this contract, but this indemnity does not apply to liability for damages arising from the sole negligence, active negligence, or willful acts of the City; and does not apply to any passive negligence of the City unless caused at least in part by the Design Professional. The City agrees that in no event shall the cost to defend charged to the Design Professional exceed that professional' s proportionate percentage of fault. This duty to indemnify shall not be waived or modified by contractual agreement or acts of the parties.
Professional Liability. When the law establishes a professional standard of care for Consultant's services, to the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless Indemnitees against, and will hold and save them and each of them harmless from, whether actual or threatened, any and all Claims and Liabilities, consistent with all obligations provided for in this Section 5.3, to the extent same are caused in whole or in part by any negligent or wrongful act, error or omission, or reckless or willful misconduct of Indemnitors in the performance of professional services under this Agreement.
ARTICLE 6. RECORDS, REPORTS AND RELEASE OF INFORMATION
Records. Consultant shall keep, and require subcontractors to keep, such ledgers, books of accounts, invoices, vouchers, canceled checks, reports, studies or other documents relating to the disbursements charged to City and services performed hereunder ("books and records") as shall be necessary to perform the services required by this Agreement and enable City to evaluate the performance of such services. Any and all such books and re ords shall be maintained in accordance with generally accepted accounting principles, shall be complete and detailed, and shall be readily accessible. City shall have full and free access to such books and records at all times during normal business hours of City, including the right to inspect, copy, audit and make records and transcripts. Such books and records shall be maintained for a period of three (3) years following completion of the services hereunder. City shall have access to such books and records in the event any audit is required. Consultant shall fully cooperate with City in providing access to any and all Consultant records and documents if a public records request is made and disclosure is required by law including but not limited to the California Public Records Act.
Ownership of Documents. All drawings, specifications, maps, designs, photographs, studies, surveys, data, notes, computer files, reports, records, documents and other materials ("documents and materials") prepared by Consultant, its officers, employees, agents and subcontractors in the performance of this Agreement shall be the property of City and shall be delivered to City upon request of City and/or upon the termination of this Agreement, and Consultant shall have no claim for further employment or additional compensation as a result of the exercise by City of its full rights of ownership, use, reuse, or assignment of the documents and materials hereunder. Consultant may retain copies of such documents and materials for its own use. Consultant shall have the right to use the concepts embodied therein. All subcontractors shall provide for assignment to City of any documents and materials prepared by them, and in the event Consultant fails to secure such assignment, Consultant shall indemnify City for all damages resulting therefrom. Moreover, with respect to any Consultant documents and materials that may qualify as "works made for hire" as defined in 17 U.S.C. § 101, such documents and materials are hereby deemed "works made for hire" for City.
Confidentiality and Release of Information. All information gained or work product produced by Consultant in its performance of this Agreement shall be considered confidential, unless such information is in the public domain or already known to Consultant. Consultant shall not release or disclose any such information or work product to persons or entities other than City without prior written authorization from City. Consultant, its officers, employees, agents or subcontractors, shall not, without prior written authorization from City or unless requested by the City Attorney, voluntarily provide documents, declarations, letters of support, testimony at depositions, response to interrogatories or other information concerning the work performed under this Agreement. Response to a subpoena or court order shall not be considered "voluntary" provided Consultant immediately gives City notice of such court order or subpoena. If Consultant, or any officer, employee, agent or subcontractor of Consultant, provides any information or work product in violation of this Agreement, then City shall have the right to reimbursement and indemnity from Consultant for any damages, costs and fees, including attorney's fees, caused by or incurred as a result of Consultant's conduct. As concerning, regarding or related to, in any way, this Agreement and the work performed thereunder: a) Consultant shall immediately notify City should Consullanl, ils offict:rs, t:rnployt:t:s, agt:nls or subconlradurs bt: st:rved with any summons, complaint, subpoena, notice of deposition, request for documents, interrogatories, request for admissions or other discovery request, court order or subpoena from any party; b) City retains the right, but has no obligation, to represent Consultant or be present at any deposition, hearing or similar proceeding; and, c) Consultant agrees to cooperate fully with City and to provide City with the opportunity to review any response to discovery requests provided by Consultant, however, this right to review any such response does not imply or mean the right hy City to control, direct, or rewrite said response.
ARTICLE 7. ENFORCEMENT OF AGREEMENT AND TERMINATION
California Law. This Agreement shall be interpreted, construed and governed both as to validity and to performance of the Parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim or matter arising out of or in relation to this Agreement shall be instituted in the Superior Court of the County of Riverside, State of California, or any other appropriate court in such county, and Consultant agrees to submit to the personal jurisdiction of such court in the event of such action. In the event oflitigation in a U.S. District Court, venue shall lie exclusively in the Central District of California, in the County of Riverside, State of California.
Suspension, or Termination, Prior to Expiration of Term. This Section shall govern any termination of this Agreement except as specifically provided in Section
7.4 for termination for cause. City reserves the right to terminate or suspend this Agreement, or any portion hereof, at any time, for any reason, with or without cause, upon ten (10) days' notice to Consultant, except that where termination or suspension is due to the fault of Consultant, the period of notice may be such shorter time as determined by City. Upon receipt of any notice of termination or suspension, Consultant shall immediately cease all services hereunder, unless the notice provides otherwise, or except such as specifically approved by City. Upon submittal of an invoice consistent with Section 2.2, Consultant shall be entitled to compensation for all services rendered prior to the effective date of the notice of termination or suspension and for any services authorized by City thereafter in accordance with the Schedule of Compensation, or such as may be approved by City, except as provided in Section 7.5. In event of termination, or suspension, without cause pursuant to this Section, there is no need to provide opportunity to cure pursuant to Section 7.3.
Default of Consultant and Opportunity to Cure. In the event that Consultant is in default under the terms of this Agreement, City shall not have any obligation or duty to continue compensating Consultant for any work performed after the date of default. Instead, City may give notice to Consultant of the default and the reasons for the default. The notice shall include the timeframe in which Consultant may cure the default. This timeframe is presumptively ten (10) days, but may be extended, or reduced, if circumstances warrant, as determined by City. During the period of time that Consultant is in default, City shall hold all invoices and shall, when the default is cured, proceed with payment on the invoices, without liability for interest. In the alternative, City may, in its sole discretion, elect to pay some or all of the outstanding invoices during the period of default. If Consultant does not cure the default by conclusion of noticed timeframe, City may immediately both terminate this Agreement with notice to Consultant as well as pursue the remedy in Section 7.4, without prejudice to any other remedy to which City may be entitled at law, in equity or under this Agreement. Any failure on the part of City to give notice of Consultant's default shall not be deemed to result in a waiver of City's legal rights or any rights arising out of any provision of this Agreement.
Termination for Default of Consultant. If termination is due to the failure of Consultant to fulfill its obligations under this Agreement, City may, after compliance with the provisions of Section 7.3, take over the work and prosecute the same to completion by contract or otherwise, and Consultant shall be liable to the extent that the total cost for completion of the services required hereunder exceeds the compensation herein stipulated (provided that City shall use reasonable efforts to mitigate such damages), and City may withhold any payments to Consultant for the purpose of set-off or partial payment of the amounts owed City therefor.
Retention of Funds. Consultant hereby authorizes City to deduct from any amount payable to Consultant (whether or not arising out of this Agreement) (i) any amounts the payment of which may be in dispute hereunder or which are necessary to compensate City for any losses, costs, liabilities, or damages suffered by City, and (ii) all amounts for which City may be liable to third parties, by reason of Consultant's acts or omissions in performing or failing to perform Consultant's obligation under this Agreement. In the event that any claim is made by a third party, the amount or validity of which is disputed by Consultant, or any indebtedness shall exist which shall appear to be the basis for a claim of lien, City may withhold from any payment due, without liability for interest because of such withholding, an amount sufficient to cover such claim. The failure of City to exercise such right to deduct or to withhold shall not, however, affect the obligations of Consultant to insure, indemnify, and protect City as elsewhere provided herein.
Waiver. Waiver by any Party to this Agreement of any term, condition, or covenant of this Agreement shall not constitute a waiver of any other term, condition, or covenant. Waiver by any Party of any breach of the provisions of this Agreement shall not constitute a waiver of any other provision or a waiver of any subsequent breach or violation of any provision of this Agreement. Acceptance by City of any work or services by Consultant shall not constitute a waiver of any of the provisions of this Agreement. No delay or omission in the exercise of any right or remedy by a non-defaulting Party on any default shall impair such right or remedy or be construed as a waiver. Any waiver by either Party of any default must be in writing and shall not be a waiver of any other default concerning the same or any other provision of this Agreement. Consultant acknowledges und agrees that any actual or alleged failure on the part of City to inform Consultant of non-compliance with any requirement of this Agreement imposes no additional obligations on City nor does it waive any rights hereunder. Payment to Consultant for work performed pursuant to this Agreement shall not be deemed to waive any defects in work performed by Consultant.
Rights and Remedies are Cumulative. Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the Parties are cumulative and the exercise by either Party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other Party.
Legal Action. In addition to any other rights or remedies, either Party may take legal action, in law or in equity, to cure, correct or remedy any default, to recover damages for any default, to compel specific performance of this Agreement, to obtain declaratory or injunctive relief, or to obtain any other remedy consistent with the purposes of this Agreement. Notwithstanding any contrary provision herein, Consultant shall file a statutory claim pursuant to Government Code sections 905 et seq. and 910 et seq., in order to pursue a legal action under this Agreement.
Attorneys' Fees. If either Party to this Agreement is required to initiate or defend or made a party to any action or proceeding in any way connected with this Agreement, the prevailing party in such action or proceeding, in addition to any other relief which may be granted, whether legal or equitable, shall be entitled to reasonable attorneys' fees. Attorneys' fees shall include attorneys' fees on any appeal, and a Party entitled to attorneys' fees shall be entitled to all other reasonable costs for investigating such action, consultants' fees, taking depositions and discovery and all other necessary costs the court allows which are incurred in such litigation. Such fees and costs shall be enforceable whether or not such action is prosecuted to judgment.
ARTICLE 8. INDIVIDUAL LIABILITY, CONFLICTS AND NON-DISCRIMINATION Non-liability of City Officers and Employees. No officer or employee of City shall be personally liable to Consultant, or any successor in interest, in the event of any default or breach by City or for any amount which may become due to Consultant or to its successor, or for breach of any obligation of the terms of this Agreement.
Conflict of Interest. Consultant covenants that neither it, nor any officer or principal of its firm, has or shall acquire any interest, directly or indirectly, which would conflict in any manner with the interests of City or which would in any way hinder Consultant's performance of services under this Agreement. Consultant further covenants that in the performance of this Agreement, no person having any such interest shall be employed by it as an officer, employee, agent or subcontractor without the express written consent of City. Consultant agrees to at all times avoid conflicts of interest or the appearance of any conflicts of interest with the interests of City in the performance of this Agreement. City, in its sole discretion, shall determine the existence of a conflict of interest and may terminate this Agreement in the event such a conflict of interest exists upon sending Consultant written notice describing the conflict. No officer or employee of City shall have any financial interest, direct or indirect, in this Agreement nor shall any such officer or employee participate in any decision relating to this Agreement which affects their financial interest or the financial interest of any corporation, partnership or association in which they are, directly or indirectly, interested, in violation of any State statute or regulation. Consultant warrants that it has not paid or given and will not pay or give any third party any money or other consideration for obtaining this Agreement.
Covenant Against Discrimination. Consultant covenants that, by and for itself, its heirs, executors, assigns, and all persons claiming under or through them, that there shall be no discrimination against or segregation of, any person or group of persons on account of race, color, creed, religion, sex, gender, sexual orientation, marital status, national origin, ancestry or other protected class in the performance of this Agreement. Consultant shall take affirmative action to insure that applicants are employed and that employees are treated during employment without regard to their race, color, creed, religion, sex, gender, sexual orientation, marital status, national origin, ancestry or other protected class.
ARTICLE 9. MISCELLANEOUS PROVISIONS
Notices. Any notice or other communication either Party desires or is required to give to the other Party or any other person in regards to this Agreement must be in writing and may be given either by (i) personal service, (ii) delivery by a reputable document delivery service, such as but not limited to, Federal Express, which provides a receipt showing date and time of delivery, or (iii) mailing in the United States Mail, certified mail, postage prepaid, return receipt requested, in the case of City addressed to City Clerk at City of Murrieta, 1 Town Square, Murrieta California 92562, and in the case of Consultant, to the person(s) at the address designated on the cover page of this Agreement. Either Party may change its address by notifying the other Party of the change of address in writing. Notice shall be deemed communicated at the time personally delivered or in seventy-two (72) hours from the time of mailing if mailed as provided in this Section.
Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either Party by reason of the authorship of this Agreement, headings used, or any other rule of construction which might otherwise apply.
Counterparts. This Agreement may be executed in counterparts, each of which shall be deemed an original, and such counterparts shall constitute one and the same instrument.
Integration; Amendment. This Agreement including the attachments hereto is the entire, compiete and exciusive expression of the understanding of the Parties as to the Agreement. It is understood that there are no oral agreements between the Parties hereto affecting this Agreement, and this ,A._greement supersedes and cancels any and all prior and contemporaneous negotiations, arrangements, agreements and understandings, if any, between the Parties, concerning this Agreement, and none shall be used to interpret this Agreement. No amendment to or modification of this Agreement shall be valid unless made in writing and approved by Consultant and by City.
Severability. Should a portion of this Agreement be declared invalid or unenforceable by a judgment or decree of a court of competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining portions of this Agreement which are hereby declared as severable and shall be interpreted to carry out the intent of the Parties unless the invalid provision is so material that its invalidity deprives either Party of the basic benefit of their bargain or renders this Agreement meaningless.
No Undue Influence. Consultant declares and warrants that no undue influence or pressure was used against or in concert with any officer or employee of City in connection with the award, terms or implementation of this Agreement, including any method of coercion, confidential financial arrangement, or financial inducement. No officer or employee of City has or will receive compensation, directly or indirectly, from Consultant, or from any officer, employee or agent of Consultant, in connection with the award of this Agreement or any work to be conducted as a result of this Agreement. Violation of this Section shall be a material breach of this Agreement entitling City to remedies in Section 7.4 and any and all remedies at law or equity.
Corporate Authority. The persons executing this Agreement on behalf of the Parties hereto warrant that (i) such Party is duly organized and existing, (ii) they are duly authorized to execute and deliver this Agreement on behalf of said Party, (iii) by so executing this Agreement, such Party is formally bound to the provisions of this Agreement, and (iv) entering into this Agreement does not violate any provision of any other agreement to which said Party is bound. This Agreement shall be binding upon the heirs, executors, administrators, successors and assigns of the Parties.
Federal Funding. If federal funding is being utilized to fund any part of the Project, as indicated on the Cover Page of this Agreement, the terms of Exhibit Fare hereby incorporated herein by this reference. If no federal funding is being utilized, Exhibit F may be omitted. [SIGNATURES ON FOLLOWING PAGE]
IN WITNESS WHEREOF, the Parties hereto have executed this Agreement on the date and year first-above written.
CITY:
CITY OF MURRIETA, a California municipal corporation
ATTEST:
B:
Kim Summers, City Manager
Effective Date:
Cristal McDonald, City Clerk Date:
APPROVED AS TO FORM: ALESHIRE & \VYNDER, LLP
Tiffany Israel, City Attorney Date:
CONSULTANT:
Two corporate officer signatures required when Consultant is a corporation, with one signature required from each of the following groups: 1) Chairperson of the Board, President or any Vice President; and 2) Secretary, any Assistant Secretary, Chief Financial Officer or any Assistant Treasurer. (Cal. Corp. Code § 313.) Appropriate attestations shall be included as may be required by the bylaws, articles of incorporation or other rules or regulations applicable to Consultant's business City.
By: _ Name: Click or tap here to enter text.
Title: Click or tap here to enter text.
Date:
By: _ Name:Click or tap here to enter text.
Title:Click or tap here to enter text.
Date:
01375.0001/964368.1 -15-
EXHIBIT "A" SCOPE OF SERVICES
Consultant will perform the following types of Services associated with vertical construction and project management services on an on-call basis:
Scope of Work
Design and Consulting Services
Facility Master planning-including initial planning, needs assessment, space requirements, budgets, and phasing plans.
City facility program management
Provide, analyze, and evaluate various construction delivery methods for City consideration Assist with development of project budgets
Bidding I Design-Build Request For Qualifications and Proposals assistance Develop project schedules Identify and analyze possible project financing options Construction project cost estimates (hard and soft costs) Value engineering Review of building systems
Formal constructability review and consultation and value engineering Consideration of life cycle costs
Stimulate bid / proposal interest
Pre-qualify / Qualify bids/ proposals including evaluation of bonds, insurance coverage and financial capability Clarify scope of each trade
Assistance with possible pre-purchase of long lead time materials 01375.0001/964368.l
Assist in the conduct of pre-bid / pre-proposal and pre-construction meetings Construction Management As-needed pre-construction services
Project Management- including scheduling, project budgeting, and providing reporting via project management information systems.
Work with Owner, Architect, and General Contractor to clearly define roles and responsibilities during construction and develop a construction management plan.
Coordinate the work of the General Contractor without interfering in the progress of the project and make them a part of the project team.
Manage and conduct meetings with Owner, Architect, and General Contractor and produce minutes from each meeting. Assure that the project is on schedule and if not, develop recovery pians with Generai Contractor.
Establish notification procedures for any shutdowns of utilities for the progress of the work.
Coordinate the testing and inspection of the project and review test reports and make recommendations as necessary.
Assist the City with preparing any RFPs/request for quotes/bids for other types of vendor needs that may be required. Examples included but are not limited to, specialty design subconsultants, and fixtures, furnishings and equipment needs.
Coordinate the activities of the multiple contracts between projects to assure that they are not interfering with each other.
Produce monthly cost reports to monitor the current and project final costs of the project. Prepare cash flow projections as needed.
Provide administrative assistance to manage the filing systems, meeting minutes and the office. Develop and maintain correspondence logs.
Review and make recommendations on change order requests from the General Contractor. Determine if the requests are legitimate, and/or negotiate as appropriate.
Review any Owner or design team document changes and prepare cost estimates for each. Maintain a change order log reflecting the status of each change order and the total cost of changes. 01375.0001/964368.l 145610
Develop and maintain submittal and shop drawing logs. Review both as they are received before transmittal to the design teams to assure that they are complete and accurate.
Develop and maintain a Request for Information (RFI) logs. Coordinate and track responses with the design teams.
Produce weekly management report summary defining the progress of the work including change orders, RFI's, submittals, schedule and potential claims. Produce a more detailed monthly report of the same items.
Review the monthly payment requests for completeness and accuracy including proper payroll documentation and lien releases and make recommendation for payment to Owner.
Monitor the construction schedule provided by the General Contractor. Provide progress photos and video taping of the project on a regular basis.
Review any potential claims. If any are received, review them, and make recommendations.
Field inspection to evaluate work in progress to confirm that it conforms to the contract documents. City seeks generalist inspection skills related to building systems such as mechanical, electrical, plumbing and telecommunications. City may also want the Construction Manager to satisfy the inspection requirements for essential service facility rating of the buildings.
Schedule City and special inspections.
Work with all local and government agencies to keep them informed of the progress of the project. Meet with them as required.
Monitor the General Contractors' safety program. Labor compliance reporting/documentation review.
Prepare, in conjunction with the design team and Owner, all punch-lists. Monitor the completion of the punch-lists by the General Contractor.
Coordinate and receive all close-out items including as-built drawings, operation and maintenance manuals, and warranties as required.
Assist with resolving all contract issues, warranties, bonds, etc. at closeout of project. Maintain any and all records to ensure labor compliance.
Prepare a final close out report with recommendation as to final payment to contractor, notice of 01375.0001/964368.l 145610
completion, and file system for retrieval of closeout documentation. Assist with commissioning the building and owner training.
Consultant must perform all on-call Services in compliance with the following requirements:
Each task shall be indicated by a written request ("Task Order") produced by the Department Contact with a description of the work to be performed, and the time desired for completion. All tasks shall be carried out in conformity with all provisions of this Agreement.
Consultant must prepare a written description of the requested tasks including all components and subtasks; the costs to perform the task ("Task Budget"), using the itemized fees in Exhibit C, Schedule of Compensation; whenever a requested task is provided for in Exhibit C; explain how the cost was determined; and, a schedule for completion of the task ("Task Completion Date"); which shall all collectively be referred to as the "Task Proposal".
Department Contact shall in writing approve, modify or reject the Task Proposal, and may issue a Task Order.
The task shall be performed at a cost not to exceeding the Task Budget.
Consultant shall complete the task and deliver all deliverables to Department Contact by the Task Completion Date.
In addition to any other requirements of this Agreement, during performance of the Services, Consultant will keep the City appraised of the status of performance by delivering the following status reports:
Biweekly status reports
All work product is subject to review and acceptance by the City, and must be revised by the Consultant without additional charge to the City until found satisfactory and accepted by City.
Consultant will utilize the following personnel to accomplish the Services:
TBD
01375.0001/964368.1 145610
EXHIBIT "B" SPECIAL REQUIREMENTS
(Superseding Contract Boilerplate)
NIA
01375.0001/964368.l 145610
EXHIBIT "C" SCHEDULE OF COMPENSATION
Consultant shall establish a Task Budget for each Task identifying the subtasks, based on the time and rates of the personnel performing the subtasks, and itemizing all materials and equipment utilized and the costs thereof. If payment is to be made other than at completion of the services, then the phases of the performance and percentage of payment due shall also be shown in the Task Proposal. •City will compensate Consultant for the Services performed upon submission of a valid invoice. Each invoice is to include Line items for all personnel describing the work performed, the number of hours worked, and the hourly rate.
Line items for all materials and equipment properly charged to the Services.
Line items for all other approved reimbursable expenses claimed, with supporting documentation.
Line items for all approved subcontractor labor, supplies, equipment, materials, and travel properly charged to the Services.
The total compensation for all Services during the entire term of this Agreement shall not exceed the Contract Sum as provided in the Cover Page of this Agreement.
Consultant's billing rates for any hourly Services are attached as Exhibit C-1.
In connection with the services provided pursuant to the terms of this Agreement, City will pay Consultant upon City's receipt of a written invoice provided by Consultant no more than monthly. City will pay Consultant for work completed, billed in increments of six minutes (0.1 hours), not to exceed the Contract Sum. The City will reimburse the Consultant for reasonable out-of-pocket expenses related to performing services on behalf of the Client that are approved in advance in writing by the City such as mileage, copies, binding costs, postage, parking, travel, and lodging expenses as part of the not to exceed Contract Sum. To receive reimbursements, the Consultant must provide the City with a receipt and a description of the expense incurred along with the invoice. No mark up on expenses may be added. 01375.0001/964368.1 1456 IO
EXHIBIT C-1
6 FEE PROPOSAL
Griffin StructuresGriffin Structures
Griffin Structures
Griffin Structures
Pricing Information Structure
11 The hourly rate(s) to be paid to the selected firm for general consultation will be for staff hours and expenses accrued in producing the required services, up to a maximum annual compensation to be determined by the City. Identify any annual incremental increases for the hourly rate(s), in percentage form, if applicable. The City will not reimburse the selected firm for mileage nor the use of computer equipment."
PROGRAM & CONSTRUCTION MANAGEMENT
TITLE 2024
2025
2026
2027
2028
BLENDED
CEO
$290
$305
$320
$320
$345
$316
CFO
$275
$290
$305
$305
$330
$301
President
$265
$280
$295
$295
$320
$291
Project Executive
$250
$265
$280
$280
$305
$276
Predevelopment Manager
$250
$265
$280
$280
$305
$276
Sr. Program & Construction Manager
$240
$250
$265
$265
$290
$262
Program & Construction Manager
$235
$245
$260
$260
$285
$257
Inspector
$220
$230
$240
$240
$260
$238
Sr. Program Analyst
$220
$230
$240
$240
$260
$238
Estimator
$220
$230
$240
$240
$260
$238
Program Analyst
$215
$225
$235
$235
$255
$233
Accounting
$210
$220
$230
$230
$250
$228
- GRIFFIN
STRUCTURES
EXHIBIT "D" SCHEDULE OF PERFORMANCE
Consultant shall perform Services on an on-call basis as set forth in Exhibit A.
Consultant shall deliver the following tangible work products to the City by the following dates.
TBD based on Project Specific Quote
Ill. The Department Contact may approve extensions for performance of the Services under any specific Task Order in accordance with Section 3.2. 01375.0001/964368. l
EXHIBITE INSURANCE REQUIREMENTS
Consultant shall procure and maintain for the duration of the contract insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Consultant, its agents, representatives, or employees.
MINIMUM SCOPE AND LIMIT OF INSURANCE
Coverage shall be at least as broad as:
Commercial General Liability (CGL): Insurance Services Office Form CG 00 01 covering CGL on an "occurrence" basis, including products and completed operations, propertJ' damage, bodily irJur; and personal & advertising injUr)' vlith limits no less than $2,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit.
Automobile Liability: Insurance Services Office Form Number CA 0001 covering, Code 1 (any auto), or if Consultant has no owned autos, Code 8 (hired) and 9 (non-owned), with limit no less than $1,000,000 per accident for bodily injury and property damage.
Workers' Compensation insurance as required by the State of California, with Statutory Limits, and Employer's Liability Insurance with limit of no less than $1,000,000 per accident for bodily injury or disease. (Not required if consultant provides written verification it has no employees) Professional Liability (Errors and Omissions) Insurance appropriates to the Consultant's profession, with limit no less than $2,000,000 per occurrence or claim, $2,000,000 aggregate.
Cyber: Vendor/Consultant shall procure and maintain for the duration of the contract insurance against claims for security breaches, system failures, injuries to persons, damages to software, or damages to property (including computer equipment) which may arise from or in connection with the performance of the work hereunder by the Vendor, its agents, representatives, or employees. Vendor shall procure and maintain for the duration of the contract insurance claims arising out of their services and including, but not limited to loss, damage, theft or other misuse of data, infringement of intellectual property, invasion of privacy and breach of data.
Cyber Liability Insurance, with limits not less than $2,000,000 per occurrence or claim, $2,000,000 aggregate. Coverage shall be sufficiently broad to respond to the duties and obligations as is undertaken by Vendor in this agreement and shall include, but not be 01375.0001/964368.I
limited to, claims involving security breach, system failure, data recovery, business interruption, cyber extortion, social engineering, infringement of intellectual property, including but not limited to infringement of copyright, trademark, trade dress, invasion of privacy violations, information theft, damage to or destruction of electronic information, release of private information, and alteration of electronic information. The policy shall provide coverage for breach response costs, regulatory fines and penalties as well as credit monitoring expenses.
Technology Professional Liability Errors & Omissions
(Only if vendor is providing a technology service (data storage, website designers, etc.,) or product (software providers) Technology Professional Liability Errors and Omissions Insurance appropriate to the Consultant's profession and work hereunder, with limits not less than $2,000,000 per occurrence. Coverage shall be sufficiently broad to respond to the duties and obligations as is undertaken by the Vendor in this agreement and shall include, but not be limited to, claims involving security breach, system failure, data recovery, business interruption, cyber extortion, social engineering, infringement of intellectual property, including but not limited to infringement of copyright, trademark, trade dress, invasion of privacy violations, information theft, damage to or destruction of electronic information, release of private information, and alteration of electronic information. The policy shall provide coverage for breach response costs, regulatory fines and penalties as well as credit monitoring expenses. a. The Policy shall include, or be endorsed to include, property damage liability coverage for damage to, alteration of, loss of, or destruction of electronic data and/or information "property" of the Agency in the care, custody, or control of the Vendor.
If the Consultant maintains broader coverage and/or higher limits than the minimums shown above, the City requires and shall be entitled to the broader coverage and/or the higher limits maintained by the consultant. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City.
Other Insurance Provisions
The insurance policies are to contain, or be endorsed to contain, the following provisions:
Additional Insured Status
The City, its officers, officials, employees, and volunteers are to be covered as additional insureds on the CGL policy with respect to liability arising out of work or operations performed by or on behalf of the Consultant including materials, parts, or equipment furnished in connection with such work or operations. General liability coverage can be provided in the form of an endorsement to the Consultant's insurance (at least as broad as ISO Form CG 20 10 11 85 or if not available, through the addition of both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 if a later edition is used).
Primary Coverage
For any claims related to this contract, the Consultant's insurance coverage shall be primary and non-contributory and at least as broad as ISO CG 20 01 04 13 as respects the City, its officers, officials, employees, and volunteers. Any insurance or self-insurance maintained by the City, its officers, officials, employees, or volunteers shall be excess of the Consultant's insurance 0 l375.000l/964368. l
and shall not contribute with it. This requirement shall also apply to any Excess or Umbrella liability policies.
Umbrella or Excess Policy
The Consultant may use Umbrella or Excess Policies to provide the liability limits as required in this agreement. This form of insurance will be acceptable provided that all of the Primary and Umbrella or Excess Policies shall provide all of the insurance coverages herein required, including, but not limited to, primary and non-contributory, additional insured, Self-Insured Retentions (SIRs), indemnity, and defense requirements. The Umbrella or Excess policies shall be provided on a true "following form" or broader coverage basis, with coverage at least as broad as provided on the underlying Commercial General Liability insurance. No insurance policies maintained by the Additional Insureds, whether primary or excess, and which also apply to a loss covered hereunder, shall be called upon to contribute to a loss until the Consultant's primary and excess liability policies are exhausted.
Notice of Cancellation
Each insurance policy required above shaU provide that coverage shali not be canceled, except with notice to the City.
Waiver of Subrogation
Consultant hereby grants to City a waiver of any right to subrogation which any insurer of said Consultant may acquire against the City by virtue of the payment of any loss under such insurance. Consultant agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation, but this provision applies regardless of whether or not the City has received a waiver of subrogation endorsement from the insurer.
Self-Insured Retentions
Self-insured retentions must be declared to and approved by the City. The City may require the Consultant to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention. The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the named insured or City. The CGL and any policies, including Excess liability policies, may not be subject to a self-insured retention (SIR) or deductible that exceeds $25,000 unless approved in writing by City. Any and all deductibles and SIRs shall be the sole responsibility of Consultant or subcontractor who procured such insurance and shall not apply to the Indemnified Additional Insured Parties. City may deduct from any amounts otherwise due Consultant to fund the SIR/deductible. Policies shall NOT contain any self-insured retention (SIR) provision that limits the satisfaction of the SIR to the Named. The policy must also provide that Defense costs, including the Allocated Loss Adjustment Expenses, will satisfy the SIR or deductible. City reserves the right to obtain a copy of any policies and endorsements for verification.
Acceptability of Insurers
Insurance is to be placed with insurers authorized to conduct business in the state with a current A.M. Best's rating of no less than A:VII, unless otherwise acceptable to the City. 01375.0001/964368.l
Claims Made Po.licies (note - should be applicable onJy to professional liability, see below) If any of the required policies provide claims-made coverage:
The Retroactive Date must be shown, and must be before the date of the contract or the beginning of contract work.
Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of the contract of work.
If coverage is canceled or non-renewed, and not replaced with another claims-made policy form with a Retroactive Date prior to the contract effective date, the Consultant must purchase "extended reporting" coverage for a minimum of five (5) years after completion of work.
Verification of Coverage
Consultant shall furnish the City with original certificates and amendatory endorsements or copies of the applicable policy language effecting coverage required by this clause and a copy of the Declarations and Endorsements Pages of the CGL and any Excess policies listing all policy endorsements. All certificates and endorsements and copies of the Declarations & Endorsements pages are to be received and approved by the City before work commences. However, failure to obtain the required documents prior to the work beginning shall not waive the Consultant's obligation to provide them. The City reserves the right to require complete, certified copies of all required insurance policies, including endorsements required by these specifications, at any time. City reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances.
Subcontractors
Consultant shall require and verify that all subcontractors maintain insurance meeting all the requirements stated herein, and Contractor shall ensure that City is an additional insured on insurance required from subcontractors.
Duration of Coverage
CGL & Excess liability policies for any construction related work, including, but not limited to, maintenance, service, or repair work, shall continue coverage for a minimum of 5 years for Completed Operations liability coverage. Such Insurance must be maintained, and evidence of insurance must be provided for at least five (5) years after completion of the contract of work.
Special Risks or Circumstances
City reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances. 01375.0001/964368.l
EXHIBIT F FEDERAL REQUIREMENTS
(Only applicable if required on cover page of agreement) 01375.0001/964368.I