Attachment A
PSA with Ardurra Group, Inc.
ON-CALL PROFESSIONAL SERVICES AGREEMENT
WITH ARDURRA GROUP, INC. FOR
ON-CALL CIVIL ENGINEERING SERVICES
THIS ON-CALL PROFESSIONAL SERVICES AGREEMENT (Agreement) is made and entered into as of this 2th day of , 2026 , by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city City), and ARDURRA GROUP, INC., a Florida Corporation whose address is 1000 N.W. 57th Court, Suite 800, Miami, FL 33126, and is made with reference to the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Consultant to provide civil engineering and related services on an as-needed basis
C. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the professional services described in this Agreement.
D. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows:
1. TERM
The term of this Agreement shall commence on the Effective Date, and shall terminate on , 2031, unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
2.1 Consultant shall perform the on-call services described in the Scope of Consultant shall provide a letter proposal for Services requested by the City (hereinafter
2.1.1 A detailed description of the Services to be provided;
2.1.2 The position of each person to be assigned to perform the Services, and the name of the individuals to be assigned, if available; Ardurra Group, Inc. Page 2
2.1.3 The estimated number of hours and cost to complete the Services; and
2.1.4 The time needed to finish the specific project.
2.2 No Services shall be provided until the Project Administrator has provided written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall diligently perform the duties in the approved Letter Proposal.
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this Agreement and Consultant shall perform the Services in accordance with the schedule included in Exhibit A and the Letter Proposal. In the absence of a specific schedule, the Services shall be performed to completion in a diligent and timely manner. The failure by Consultant to strictly adhere to the schedule set forth in Exhibit A and the Letter Proposal, if any, or perform the Services in a diligent and timely manner may result in termination of this Agreement by City.
3.2 Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Co However, in the case of
any such delay in the Services to be provided for the Project, each party hereby agrees to provide notice within two (2) calendar days of the occurrence causing the delay to the other party so that all delays can be addressed.
3.3 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator as defined herein not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that a
3.4 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by hand-delivery or mail.
4. COMPENSATION TO CONSULTANT
4.1 City shall pay Consultant for the Services on a time and expense not-to- exceed basis in accordance with the provisions of this Section and the Letter Proposal and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Work performed in accordance with this
Agreement, including all reimbursable items and subconsultant fees, shall not exceed Five Hundred Thousand Dollars and 00/100 ($500,000.00), without prior written authorization from City. No billing rate changes shall be made during the term of this Agreement without the prior written approval of City.
4.2 Upon the first anniversary of the Effective Date and upon each anniversary Ardurra Group, Inc. Page 3
may be adjusted in proportion to changes in the Consumer Price Index, subject to the maximum adjustment set forth below. Such adjustment, if agreed to by both City and Consultant, shall be made by multiplying the Billing Rates in Exhibit B by a fraction, the numerator of which is the value of the Consumer Price Index for the calendar month three (3) months preceding the calendar month for which such adjustment is to be made, and the denominator of which is the value of the Consumer Price Index for the same calendar month immediately prior to Effective Date. The Consumer Price Index to be used in such -84=100 for All Urban
Consumers (CPI- -Riverside-Orange County Metropolitan Area, published by the United States Department of Labor, Bureau of Labor Statistics. If both an official index and one or more unofficial indices are published, the official index shall be used. If said Consumer Price Index is no longer published at the adjustment date, it shall be constructed by conversion tables included in such new index. In no event, however, shall the amount payable under this Agreement reduced below the Billing Rates in effective immediately preceding such adjustment. The maximum adjustment increase to the Billing Reats, for any year where an adjustment is made pursuant to this Section, shall not exceed the Consumer Price Index or 3.0% of the Billing Rates in effect immediately preceding such adjustment, whichever is less. Consultant shall notify City in writing of any request for adjustment pursuant to this Section at least thirty (30) days prior to the Effective Date of such adjustment and provide updated billing rates. Adjusted billing rates shall be approved in writing by City prior to use.
4.3 Consultant shall submit monthly invoices to City describing the Work who performed the Work, a brief description of the Services performed and/or the specific task in the Scope of Services to which it relates, the date the Services were performed, the number of hours spent on all Work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar days after approval of the monthly invoice by City staff.
4.4 City shall reimburse Consultant only for those costs or expenses specifically identified in Exhibit B to this Agreement and the Letter Proposal or specifically approved in writing in advance by City.
4.5 Consultant shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, Extra Work means any Work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement.
Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates as set forth in Exhibit B and the Letter Proposal.
5. PROJECT MANAGER
5.1 Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated Ryan Gallagher to be its
Ardurra Group, Inc. Page 4
Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. C approval shall not be unreasonably withheld with respect to the removal or assignment of non-key personnel.
5.2 Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of Services upon written request of City.
Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement.
5.3 If Consultant is performing inspection services for City, the Project Manager and any other assigned staff shall be equipped with a cellular phone to communicate with City staff. cellular phone number shall be provided to City.
6. ADMINISTRATION
This Agreement will be administered by the Public Works Department. City Director of Public Works or designee shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement.
7. CITY'S RESPONSIBILITIES
To assist Consultant in the execution of its responsibilities under this Agreement, City agrees to provide access to and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner Work schedule.
8. STANDARD OF CARE
8.1 All of the Services
supervision. Consultant represents that it possesses the professional and technical personnel required to perform the Services required by this Agreement, and that it will perform all Services in a manner commensurate with community professional standards and with the ordinary degree of skill and care that would be used by other reasonably competent practitioners of the same discipline under similar circumstances. All Services shall be performed by qualified and experienced personnel who are not employed by City.
By delivery of completed Work, Consultant certifies that the Work conforms to the requirements of this Agreement, all applicable federal, state and local laws, and legally recognized professional standards.
8.2 Consultant represents and warrants to City that it has, shall obtain, and shall keep in full force and effect during the term hereof, at its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement.
Ardurra Group, Inc. Page 5
8.3 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, acts of God, or the failure of City to furnish timely information or to Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9. HOLD HARMLESS
9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents, ), from and against any
and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, negligence, recklessness, or willful misconduct of the Consultant or its principals, officers, agents, employees, vendors, suppliers, subconsultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable, or any or all of them.
9.2 Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the sole negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in thi
on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant.
10. INDEPENDENT CONTRACTOR
It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the Work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. No civil service status or other right of employment shall accrue to Consultant or its employees. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of shall have the responsibility for and control over the means of performing the Work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance of the Work or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the Services.
Ardurra Group, Inc. Page 6
11. COOPERATION
Consultant agrees to work closely and cooperate fully with C designated Project Administrator and any other agencies that may have jurisdiction or interest in the Work to be performed. City agrees to cooperate with the Consultant on the Project.
12. CITY POLICY
Consultant shall discuss and review all matters relating to policy and Project direction with C Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies.
13. PROGRESS
Consultant is responsible for keeping the Project Administrator informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired.
14. INSURANCE
of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement or for other periods as specified in this Agreement, policies of insurance of the type, amounts, terms and conditions described in the Insurance Requirements attached hereto as Exhibit C, and incorporated herein by reference.
15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint-venture or syndicate or co-tenancy, which shall result in changing the control of Consultant. Control means fifty percent (50%) or more of the voting power or twenty-five percent (25%) or more of the assets of the corporation, partnership or joint-venture.
16. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are identified in Exhibit A and the Letter Proposal. Consultant shall be fully responsible to City for all acts and omissions of any subcontractor. Nothing in this Agreement shall create any contractual relationship between City and any subcontractor nor shall it create any obligation on the part of City to pay or to see to the payment of any monies due to any such subcontractor other than as otherwise required by law. City is an intended beneficiary of any Work performed by the subcontractor for purposes of establishing a duty of care between the subcontractor and City. Except as specifically authorized herein,
Ardurra Group, Inc. Page 7
the Services to be provided under this Agreement shall not be otherwise assigned, transferred, contracted or subcontracted out without the prior written approval of City.
17. OWNERSHIP OF DOCUMENTS
17.1 Each and every report, draft, map, record, plan, document and other writing produced, including but not limited to, websites, blogs, social media accounts and its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Additionally, all material posted in cyberspace by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. and password information to City upon prior written request.
17.2 Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed Documents for other projects and any use of incomplete Documents without specific written authorization from t
by City or persons other than Consultant is waived against Consultant, and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes.
17.3 C ADD data delivered to City shall
include the professional stamp of the engineer or architect in charge of or responsible for the Work. City agrees that Consultant shall not be liable for claims, liabilities or losses arising out of, or connected with (a) the modification or misuse by City, or anyone authorized by City, of CADD data; or (b) any use by City, or anyone authorized by City, of CADD data for additions to this Project, for the completion of this Project by others, or for any other Project, excepting only such use as is authorized, in writing, by Consultant.
By acceptance of CADD data, City agrees to indemnify Consultant for damages and liability resulting from the modification or misuse of such CADD data. All original drawings shall be submitted to City in the version of AutoCAD used by the City in .dwg file format,
17.4 All improvement and/or construction plans shall be plotted on standard twenty- - paper size. Consultant shall provide to City
digital - in both AutoCAD and Adobe PDF file format within thirty (30) days after finalization of the Project.
Ardurra Group, Inc. Page 8
18. OPINION OF COST
Any opinion of the construction cost prepared by Consultant represents the Consultant ed for the general guidance
of City. Since Consultant has no control over the cost of labor and material, or over competitive bidding or market conditions, Consultant does not guarantee the accuracy of such opinions as compared to Consultant or contractor bids or actual cost to City.
19. CONFIDENTIALITY
All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the Services in this Agreement, shall be kept confidential unless City expressly authorizes in writing the release of information.
20. INTELLECTUAL PROPERTY INDEMNITY
Consultant shall defend and indemnify City, its agents, officers, representatives and employees against any and all liability, including costs, for infringement or alleged infringement
Documents provided under this Agreement.
21. RECORDS
Consultant shall keep records and invoices in connection with the Services to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any Services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant under this Agreement. All such records and invoices shall be clearly identifiable.
Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Consultant shall allow inspection of all Work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Consultant under this Agreement.
22. WITHHOLDINGS
City may withhold payment to Consultant of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue Work as a result of such withholding. Consultant shall have an immediate right to appeal to the City Manager or designee with respect to such disputed sums.
Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld.
Ardurra Group, Inc. Page 9
23. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the Work accomplished by Consultant, the additional design, construction and/or restoration expense shall be borne by Consultant. Nothing in this Section is intended to limit Citythe law or any other sections of this Agreement.
24. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other Consultants in connection with the Project.
25. CONFLICTS OF INTEREST
25.1 Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the Act) and/or Government Code §§ 1090 et seq., which (1) require such persons to disclose any financial interest that may foreseeably be materially affected by the Work performed under this Agreement, and (2) prohibit such persons from making, or participating in making, decisions that will foreseeably financially affect such interest.
25.2 If subject to the Act and/or Government Code §§ 1090 et seq., Consultant shall conform to all requirements therein. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from
26. NOTICES
26.1 All notices, demands, requests or approvals, including any change in mailing address, to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first- class mail, addressed as hereinafter provided.
26.2 All notices, demands, requests or approvals from Consultant to City shall be addressed to City at:
Attn: Director of Public Works
Public Works Department
City of Newport Beach
100 Civic Center Drive
Newport Beach, CA 92660
26.3 All notices, demands, requests or approvals from City to Consultant shall be addressed to Consultant at:
Ardurra Group, Inc. Page 10
Attn: Ryan Gallagher
Ardurra Group, Inc.
1000 N.W. 57th Court, Suite 800
Miami, FL 33126
27. CLAIMS
Unless a shorter time is specified elsewhere in this Agreement, before making its final request for payment under this Agreement, Consultant shall submit to City, in writing, all claims for compensation under or arising out of this Agreement. acceptance of the final payment shall constitute a waiver of all claims for compensation under or arising out of this Agreement except those previously made in writing and identified by Consultant in writing as unsettled at the time of its final request for payment.
Consultant and City expressly agree that in addition to any claims filing requirements set forth in the Agreement, Consultant shall be required to file any claim Consultant may have against City in strict conformance with the Government Claims Act (Government Code sections 900 et seq.).
28. TERMINATION
28.1 In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non-defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof.
28.2 Notwithstanding the above provisions, City shall have the right, at its sole and absolute discretion and without cause, of terminating this Agreement at any time by giving no less than seven (7) calendar days prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for Services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form.
29. STANDARD PROVISIONS
29.1 Recitals. City and Consultant acknowledge that the above Recitals are true and correct and are hereby incorporated by reference into this Agreement.
29.2 Compliance with all Laws. Consultant shall, at its own cost and expense, comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all Work prepared by Consultant shall conform to applicable City,
Ardurra Group, Inc. Page 11
county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City.
29.3 Waiver. A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character.
29.4 Integrated Contract. This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein.
No verbal agreement or implied covenant shall be held to vary the provisions herein.
29.5 Conflicts or Inconsistencies. In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern.
29.6 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply.
29.7 Amendments. This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney.
29.8 Severability. If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect.
29.9 Controlling Law and Venue. The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange, State of California.
29.10 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because race, religious creed, color, national origin, ancestry, physical handicap, medical condition, marital status, sex, sexual orientation, age or any other impermissible basis under law.
29.11 No Fees. In the event of any dispute or legal action arising under this Agreement, the prevailing party shall not be entitled to fees.
29.12 Counterparts. This Agreement may be executed in two (2) or more counterparts, each of which shall be deemed an original and all of which together shall constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
Ardurra Group, Inc. Page 12
IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the dates written below.
APPROVED AS TO FORM:
CITY ATTORNEY
CITY OF NEWPORT BEACH,
a California municipal corporation
Date:__________________
By:_____________________________
Date:____________________
By:_____________________________
Aaron C. Harp
City Attorney
Lauren Kleiman
Mayor
ATTEST:
Date:_________________
CONSULTANT: ARDURRA GROUP,
INC., a Florida Corporation
By:_____________________________
Date:_____________________
By:_____________________________
Lena Shumway
City Clerk
Carmen Kasner
Vice President
Date:____________________
By:_____________________________
Randy Dumas
Chief Financial Officer
[END OF SIGNATURES]
Attachments: Exhibit A Scope of Services
Exhibit B Schedule of Billing Rates
Exhibit C Insurance Requirements
Ardurra Group, Inc. Page A-1
SCOPE OF SERVICES
ON-CALL CIVIL – SCOPE OF SERVICES
Civil Engineering services shall include conceptual and final design of a wide variety of City capital improvement and maintenance projects. The successful Consultant(s) shall have the ability to provide in-house services, or capacity to subconsultant, for the following areas:
Provide full plans, specifications, and estimates for a broad range of civil engineering disciplines.
Provide cost estimating and value engineering services
Provide bid support and preparation of record drawings
Provide construction support, administration, and management services Provide construction traffic control concepts and plans Provide project-specific professional surveying services Review public/private development plans and maps
Provide regulatory permitting support
Prepare various studies and supporting documentation, including hydrology and hydraulic analysis, water and sewer studies and network analysis Prepare/review NPDES reports, Water Quality Management Plan (WQMP) and Storm Water Pollution Prevention Plans (SWPPP)
Prepare maps and legal descriptions for right-of-way acquisition and easements Other engineering-related tasks, as necessary
Consultant shall perform the on-call services described in the Scope of Services. Upon written request from the City Project Administrator, Consultant shall provide a letter proposal for specific services requested by the City (hereinafter referred to as the “Letter Proposal”).
The Letter Proposal shall include, but is not limited to, the following:
A detailed description of the Scope of Services to be provided; The Contract number;
The Title/Position of each person who will be performing the work; The hourly rates of each provider; and
Any anticipated consumable, material, or ancillary cost to perform the services.
No services shall be provided until the City Project Administrator has provided written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall diligently perform the duties in the approved Letter Proposal.
Ardurra Group, Inc. Page B-1
www.ardurra.com
CATEGORY POSITION HOURLY
RATE
Designers and
Administrative
Administrative Assistant $120
Production Designer I $140
Production Designer II $155
Production Designer III $160
Production Designer IV $180
Production Designer V $195
Production Designer VI $205
Engineers
Engineering Technician$129
Engineer I $173
Engineer II $193
Engineer III $215
Engineer IV $230
Engineer V $250
Engineer VI $265
Engineer VII $280
Engineer VIII $305
Technical Director$325
Planning
Planner I $173
Planner II $193
Planner III $203
Planner IV $220
Planner V $235
Planner VI $260
Project
Management
Assistant Project Manager$265
Project Manager $280
Senior Project Manager$306
Project Director $325
Senior Project Director$345
Construction
Management
Services
Sr Construction Manager $290
Construction Manager $260
Resident Engineer* $258
Assistant Resident Engineer* $210
Public Works Inspector* $216
Scheduler $188
Doc Control*/ Labor Analyst $148
Sr Labor Compliance $199
5 YEAR FEE SCHEDULE
(2026-2031)3
OVERALL NOTES
Reimbursable Expenses (ODCs):Travel
and subsistence (other than mileage) billed
at cost, mileage at current IRS rate, and
outside production/services cost plus 10%
Subconsultants: Cost plus 10%.
Escalation:Rates subject to annual
adjustment (typically 2%), unless otherwise
specified (e.g., prevailing wage). Rates
shown end December 31, 2026.
CONSTRUCTION MANAGEMENT NOTES
1. Rates:Hourly rates include wages,
fringe, overhead, fee, and typical supplies,
tools, and equipment. Construction
management software is excluded.
2. Prevailing Wage: Rates are subject to
increases per California DIR
determinations. Billing rates will increase
proportionally, including overhead and
profit.
3. Inspection Minimums (IWC Order
#16-2001): Cancellation of 8-hour
inspection after arrival: 4-hour minimum;
Cancellation of 4-hour inspection after
arrival: 2-hour minimum
4. Public Works Requirements: Agency
must submit DIR Form PWC-100 listing
Ardurra as prime. A 0.5-hour/week per
inspector labor compliance charge applies
to all prevailing wage inspection
assignments.
5. Overtime: Asterisked positions are
billed at 1.5x for work over 8 hours/day or
Saturdays, and 2.0x for Sundays and
holidays.
Ardurra Group, Inc. Page C-1
EXHIBIT C
INSURANCE REQUIREMENTS PROFESSIONAL SERVICES
1. Provision of Insurance. Without limiting Consultant
and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Contract, policies of insurance of the type and amounts described below and in a form satisfactory to City. Consultant agrees to provide insurance in accordance with requirements set forth here. If Consultant uses existing coverage to comply and that coverage does not meet these requirements, Consultant agrees to amend, supplement or endorse the existing coverage.
2. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact Rating of A- (or higher) and Financial Size Category Class VII (or larger) in
3. Coverage Requirements.
A. W . Consultant
Liability Insurance with limits of at least one million dollars ($1,000,000) each employee for bodily injury by accident and each employee for bodily injury by disease in accordance with the laws of the State of California.
Consultant shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its City Council, boards and commissions, officers, agents, volunteers and employees.
B. General Liability Insurance. Consultant shall maintain commercial general liability insurance, and if necessary excess/umbrella liability insurance, with coverage at least as broad as provided by Insurance Services Office form CG 00 01, in an amount not less than two million dollars ($2,000,000) per occurrence, four million dollars ($4,000,000) general aggregate. The policy shall cover liability arising from bodily injury, property damage, personal and advertising injury, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract).
C. Automobile Liability Insurance. Consultant shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of Consultant arising out of or in connection with Work to be performed under this Contract, including coverage for any owned, hired, non-owned or rented
Ardurra Group, Inc. Page C-2
vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit for each accident.
D. Professional (Errors & Omissions) Insurance. Consultant shall maintain professional liability insurance that covers the Services to be performed in connection with this Agreement, in the minimum amount of two million dollars ($2,000,000) per claim and four million dollars ($4,000,000) in the aggregate. Any policy inception date, continuity date, or retroactive date must be before the Effective Date of this Agreement and Consultant agrees to maintain continuous coverage through a period no less than three years after completion of the Services required by this Agreement.
E. Excess/Umbrella Liability Insurance. If any Excess or Umbrella Liability policies are used to meet the limits of liability required by this contract, coverage, terms, conditions, and provisions and shall meet all of the insurance requirements stated in this contract, including, but not limited to, the additional insured and primary & non-contributory insurance requirements stated herein. No insurance policies maintained by the City, whether primary or excess, and which also apply to a loss covered hereunder, shall be called upon to contribute to a loss until the Consultant
exhausted.
4. Other Insurance Requirements. The policies are to contain, or be endorsed to contain, the following provisions:
A. Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this Contract shall be endorsed to waive subrogation against City, its City Council, boards and commissions, officers, agents, volunteers and employees, or shall specifically allow Consultant or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subcontractors.
B. Additional Insured Status. All liability policies including general liability, excess/umbrella liability, and automobile liability, if required, but not including professional liability, shall provide or be endorsed to provide that City, its City Council, boards and commissions, officers, agents, volunteers and employees shall be included as additional insureds under such policies.
C. Primary and Non-Contributory. Consultant
be primary insurance and/or the primary source of recovery with respect to the City, its City Council, boards and commissions, officers, agents, volunteers and employees. All liability coverage shall apply on a primary
Ardurra Group, Inc. Page C-3
basis and shall not require contribution from any insurance or self- insurance maintained by City.
D. Notice of Cancellation. All policies shall provide City with thirty (30) calendar notice of cancellation or nonrenewal of coverage (except each required coverage.
5. Additional Agreements Between the Parties. The parties hereby agree to the following:
A. Evidence of Insurance. Consultant shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along and other endorsements as specified herein for each coverage. All of the executed documents referenced in this Contract must be returned to City within ten (10) regular City business days after the date on the of
performance. Current certification of insurance shall be kept on file with City at all times during the term of this Contract. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf. At least fifteen (15) days prior to the expiration of any such policy, evidence of insurance showing that such insurance coverage has been renewed or extended shall be filed with the City. If such coverage is cancelled or reduced, Consultant shall, within ten (10) days after receipt of written notice of such cancellation or reduction of coverage, file with the City evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies. City reserves the right to require complete, certified copies of all required insurance policies, at any time.
B. C Right to Revise Requirements. The City reserves the right at any time during the term of the Contract to change the amounts and types of insurance required by giving Consultant ninety (90) calendar advance written notice of such change. If such change results in substantial additional cost to Consultant, City and Consultant may renegotiate Consultant
C. Right to Review Subcontracts. Consultant agrees that upon request, all agreements with subcontractors or others with whom Consultant enters into contracts with on behalf of City will be submitted to City for review.
Failure of City to request copies of such agreements will not impose any liability on City, or its employees. Consultant shall require and verify that all subcontractors maintain insurance meeting all the requirements stated herein, and Consultant shall ensure that City is an additional insured on insurance required from subcontractors. For CGL coverage,
Ardurra Group, Inc. Page C-4
subcontractors shall provide coverage with a format at least as broad as CG 20 38 04 13.
D. Enforcement of Agreement Provisions. Consultant acknowledges and agrees that any actual or alleged failure on the part of City to inform Consultant of non-compliance with any requirement imposes no additional obligations on City nor does it waive any rights hereunder.
E. Requirements not Limiting. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. If the Consultant maintains higher limits than the minimums shown above, the City requires and shall be entitled to coverage for higher limits maintained by the Consultant. Any available proceeds in excess of specified minimum limits of insurance and coverage shall be available to the City.
F. Self-Insured Retentions. Any self-insured retentions must be declared to and approved by City. City reserves the right to require that self- insured retentions be eliminated, lowered, or replaced by a deductible.
Self-insurance will not be considered to comply with these requirements unless approved by City.
G. City Remedies for Non-Compliance. If Consultant or any subconsultant fails to provide and maintain insurance as required herein, then City shall have the right but not the obligation, to purchase such insurance, to terminate this Agreement, or to suspend Consultant right to proceed until proper evidence of insurance is provided. Any amounts paid by from amounts payable to
Consultant or reimbursed by Consultant upon demand.
H. Timely Notice of Claims. Consultant shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Consultant under this Contract, and that involve or may involve coverage under any of the required liability policies. City assumes no obligation or liability by such notice, but has the right (but not the duty) to monitor the handling of any such claim or claims if they are likely to involve City.
I. C . Consultant shall also procure and maintain, at
its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the Work.