PROFESSIONAL SERVICES AGREEMENT
[TV and AV Production Support and Systems Maintenance Services]
THIS PROFESSIONAL SERVICES AGREEMENT (the “Agreement”) is made at Orange, California, on thi s _____ day of ____________, 20 22 (the “Effective Date”) by and between the CITY OF ORANGE, a municipal corporation (“City”), and DARREN DOERSCHEL, a sole proprietor (“Contractor”), who agree as follows:
1. Services. Subject to the terms and conditions set forth in this Agreement, Contractor shall provide to the reasonable satisfaction of City the services set forth in Exhibit “A,” which is attached hereto and incorporated herein by reference. As a material inducem ent to City to enter into this Agreement, Contractor represents and warrants that it has thoroughly investigated and considered the scope of services and fully understands the difficulties and restrictions in performing the work. The services which are th e subject of this Agreement are not in the usual course of City’s business and City relies on Contractor’s representation that it is independently engaged in the busi ness of providing such services and is experienced in performing the work.
Contractor shall perform all services in a manner reasonably satisfactory to City and in a manner in conformance with the standards of quality normally observed by an entity provid ing such services to a municipal agency. All services provided shall conform to all federal, state and local laws, rules and regulations and to the best professional standards and practices. The terms and conditions set forth in this Agreement shall control over any terms and conditions in Exhibit "A" to the contrary.
Will Kolbow, Assistant City Manager/Administrative Services Director (“City’s Project Manager”), shall be the person to whom Contractor will report for the performance of services hereunder. It is understood that Contractor’s performance hereunder shall be under the supervision of City’s Project Manager (or designee), that Contractor shall coordinate its services hereunder with City’s Project Manager to the extent required by City’s Project Manager, and that all performances required hereunder by Contractor shall be performed to the satisfaction of City’s Project Manager and the City Manager.
2. Compensation and Fees.
a. Contractor's total compensation for all services perform ed under this Agreement, shall not exceed SEVENTY-FOUR THOUSAND DOLLARS and 00/100 ($74,000.00) without the prior written authorization of City.
b. The above compensation shall include all costs, including, but not limited to, all clerical, administrative, overhead, insurance, reproduction, telephone, travel, auto rental, subsistence and all related expenses.
2.1 Term and Extension(s)
a. The Initial Term of this Agreement is one (1) year (the “Initial Term”), commencing July 1, 2022 and expiring on June 30, 2023 (the “Expiration Date”); provided, 2 however, that City has the right to extend the term of this Agreement for the following extensions and upon the following terms:
• First Extension (the “First Extension Term”) commencing July 1, 2023, and terminating June 30, 2024 , in an annual amount not to exceed SEVENTY-FOUR THOUSAND DOLLARS and 00/100 ($74,000.00) without the prior written authorization of City;
• Second Extension (the “Second Extension Term”) commencing July 1, 2024 , and terminating June 30, 2025 , in an annual amount not to exceed SEVENTY-FOUR THOUSAND DOLLARS and 00/100 ($74,000.00) without the prior written authorization of City;
b. The City Manager is hereby authorized on behalf of City to give written notice to Contractor of City’s intention to exercise each Extension (if at all) no later than thirty (30) days prior to the Expiration Date of the then -current term; provided, however, that City’s notice of its intention to extend the term of this Agreement for each Extension shall be expressly conditioned upon and subject to the approval by the City Council, in its sole and absolute discretion, of an amount sufficient to pay the compensation set forth herein for each Extension as part of its annual budget approval process prior to the beginning of each Extension. While the parties acknowledge that City is required to give its notice of intention to extend the term of this Agreement not later than thirty (30) days prior to the Expiration Date of then -current term, it is possible that the City Council’s approval of its annual budget and appropriation of funds for the Extension in question may occur thereafter. Accordingly, if the City Council fails to approve and appropriate funds sufficient to pay the amount of compensation set forth herein for an Extension, this Agreement shall terminate and be of no further force and effect as of the expiration of the then-current term. Notwit hstanding anything in this provision to the contrary, in the event City gives Contractor written notice exercising an Extension and City receives notice that appropriation of funds for the Extension in question are not available after Contractor has perfor med services under the Extension, City agrees that Contractor will be equitably compensated for all services performed under any portion of an Extension through the date of termination of the Agreement.
Except as specifically set forth herein, the terms and conditions of each Extension will be the same as the Initial Agreement.
c. Any Extension, if properly exercised, shall be memorialized in the form of an amendment to this Agreement. The City Manager is hereby authorized to approve and execute amendments to this Agreement reflecting the exercise of each Extension and the amount of compensation (including the amount of funds to be made available for additional work or services) payable to Contractor for each respective Extension
3. Payment.
a. As scheduled services are completed, Contractor shall submit to City an invoice for the services completed, authorized expenses and authorized extra work actually performed or incurred.
b. All such invoices shall state the basis for the amount invoiced, in cluding services completed, the number of hours spent and any extra work performed. 3 c. City will pay Contractor the amount invoiced within thirty (30) days after the approval of the invoice.
d. Payment shall constitute payment in full for all service s, authorized costs and authorized extra work covered by that invoice.
4. Change Orders. No payment for extra services caused by a change in the scope or complexity of work, or for any other reason, shall be made unless and until such extra services and a price therefor have been previously authorized in writing and approved by City as an amendment to this Agreement. City’s Project Manager is authorized to approve a reduction in the services to be performed and compensation therefor. All amendments shall set forth the changes of work, extension of time, and/or adjustment of the compensation to be paid by City to Contractor and shall be signed by the City’s Project Manager, City Manager or City Council, as applicable.
5. Licenses. Contractor represents that it and any subcontractors it may engage, possess any and all licenses which are required under state or federal law to perform the work contemplated by this Agreement and that Contractor and its subcontractors shall maintain all appropriate lice nses, including a City of Orange business license, at its cost, during the performance of this Agreement.
6. Independent Contractor . At all times during the term of this Agreement, Contractor shall be an independent contractor and not an employee of Cit y. City shall have the right to control Contractor only insofar as the result of Contractor’s services rendered pursuant to this Agreement. City shall not have the right to control the means by which Contractor accomplishes services rendered pursuant to this Agreement. Contractor shall, at its sole cost and expense, furnish all facilities, materials and equipment which may be required for furnishing services pursuant to this Agreement. Contractor shall be solely responsible for, and shall indemnify, def end and save City harmless from all matters relating to the payment of its subcontractors, agents and employees, including compliance with social security withholding and all other wages, salaries, benefits, taxes, exactions, and regulations of any nature whatsoever.
Contractor acknowledges that it and any subcontractors, agents or employees employed by Contractor shall not, under any circumstances, be considered employees of City, and that they shall not be entitled to any of the benefits or rights afforded employees of City, including, but not limited to, sick leave, vacation leave, holiday pay, Public Employees Retirement System benefits, or health, life, dental, long-term disability or workers’ compensation insurance benefits.
7. Contractor Not Agent. Except as City may specify in writing, Contractor shall have no authority, express or implied, to act on behalf of City in any capacity whatsoever as an agent. Contractor shall have no authority, express or implied, to bind City to any obligation whatsoever.
8. Designated Persons. Only those qualified persons authorized by City’s Project Manager, or as designated in Exhibit “A,” shall perform work provided for under this Agreement.
It is understood by the parties that clerical and other nonprofessional work may be performed by persons other than those designated.
4 9. Assignment or Subcontracting. No assignment or subcontracting by Contractor of any part of this Agreement or of funds to be received under this Agreement shall be of any force or effect unless the assignment has the prior written approval of City. City may terminate this Agreement rather than accept any proposed assignment or subcontracting. Such assignment or subcontracting may be approved by the City Manager or his/her designee.
10. Time of Completion . Except as otherwise specified in Exhibit “A,” Contractor shall commence the work provided for in this Agreement upon commencement of the Initial Term of this Agreement and diligently prosecute completion of the work in accordance with the time period set forth in Exhibit “A” hereto or as otherwise agreed to by and between the representatives of the parties.
11. Time Is of the Essence. Time is of the essence in this Agreement. Contractor shall do all things necessary and incidental to the prosecution of Contractor’s work.
12. Reserved.
13. Delays and Extensions of Time. Contractor's sole remedy for delays outside its control, other than those delays caused by City, shall be an extension of time. No matter what the cause of the delay, Contractor must document any delay and request an extension of time in writing at the time of the delay to the satisfaction of City. Any extensions granted shall be limited to the length of the delay outside Contractor’s control. If Contractor believes that delays caused by City will cause it to incur additional costs, it must specify, in writing, why the delay has caused additional costs to be incurred and the exact amount of such cost at the time the delay occurs. No additional costs can be paid that exceed the not to exceed amount stated in Section 2.a, above, absent a written amendment to this Agreement.
14. Products of Contractor. The documents, studies, evaluations, asses sments, reports, plans, citations, materials, manuals, technical data, logs, files, designs and other products produced or provided by Contractor for this Agreement shall become the property of City upon receipt. Contractor shall deliver all such products to City prior to payment for same. City may use, reuse or otherwise utilize such products without restriction.
15. Equal Employment Opportunity . During the performance of this Agreement, Contractor agrees as follows:
a. Contractor shall not discriminate against any employee or applicant for employment because of race, color, religion, sex, national origin, mental or physical disability, or any other basis prohibited by applicable law. Contractor shall ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, sex, national origin, mental or physical disability, or any other basis prohibited by applicable law.
Such actions shall include, but not be limited to the following: employment, upgrading, demotion or transfer, recruitment or recruitment advertising, layoff or termination, rates of pay or other forms of compensation and selection for training, including apprenticeship. Contractor agrees to post in conspicuous places, available to employees and applicants for employment, a notice setting forth provisions of this non-discrimination clause.
5 b. Contractor shall, in all solicitations and advertisements for employees placed by, or on behalf of Contractor, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, sex, national origin, mental or physical disability, or any other basis prohibited by applicable law.
c. Contractor shall cause the foregoing paragraphs (a) and (b) to be inserted in all subcontracts for any work covered by this Agreement, provided that the foregoing provisions shall not apply to subcontracts for standard commercial supplies or raw materials.
16. Conflicts of Interest. Contractor agrees that it shall not make, participate in the making, or in any way attempt to use its position as a consultant to influence any decision of City in which Contractor knows or has reason to know that Contractor, its officers, partners, or employees have a financial interest as defined in Section 87103 of the Government Code.
17. Indemnity.
a. To the fullest extent permitted by law , Contractor agrees to indemnify, defend and hold City, its City Council and each member thereof, and the officers, officials, agents and employees of City (collectively the “Indemnitees”) entirely harmless from all liability arising out of:
(1) Any and all claims under workers’ compensation acts and other employee benefit acts with respect to Contractor’s employees or Contractor’s subcontractor’s employees arising out of Contractor’s work under this Agreement, including any and all claims under any law pertaining to Contractor or its employees’ status as an independent contractor and any and all claims under Labor Code section 1720 related to the payment of prevailing wages for public works projects; and
(2) Any claim, loss, injury to or death of persons or damage to property caused by any act, neglect, defa ult, or omission other than a professional act or omission of Contractor, or person, firm or corporation employed by Contractor, either directly or by independent contract, including all damages due to loss or theft sustained by any person, firm or corporation including the Indemnitees, or any of them, arising out of, or in any way connected with the work or services which are the subject of this Agreement, including injury or damage either on or off City’s property; but not for any loss, injury, death or damage caused by the active negligence or willful misconduct of City. Contractor, at its own expense, cost and risk, shall indemnify any and all claims, actions, suits or other proceedings that may be brought or instituted against the Indemnitees on any such claim or liability covered by this subparagraph, and shall pay or satisfy any judgment that may be rendered against the Indemnitees, or any of them, in any action, suit or other proceedings as a result of coverage under this subparagraph.
b. To the ful lest extent permitted by law, and as limited by California Civil Code 2782.8, Contractor agrees to indemnify and hold Indemnitees harmless from all liability arising out of any claim, loss, injury to or death of persons or damage to property to the extent caused by its negligent professional act or omission in the performance of professional services pursuant to this Agreement.
6 c. Except for the Indemnitees, the indemnifications provided in this Agreement shall not be construed to extend any third party indemnification rights of any kind to any person or entity which is not a signatory to this Agreement.
d. The indemniti es set forth in this section shall survive any closing, rescission, or termination of this Agreement, and shall continue to be binding and in full force and effect in perpetuity with respect to Contractor and its successors.
18. Insurance
a. Contractor shall carry workers’ compensation insurance as required by law for the protection of its employees during the progress of the work. Contractor understands that it is an independent contractor and not entitled to any worker s’ compensation benefits under any City program.
b. Contractor shall maintain during the life of this Agreement the following minimum amount of comprehensive general liability insurance or commercial general liability insurance: the greater of (1) One Million Dollars ( $1,000,000) per occurrence ; or (2) all the insurance coverage and/or limits carried by or available to Contractor. Said insurance shall cover bodily injury, death and property damage and be written on an occurrence basis.
c. Contractor shall maintain during the life of this Agreement, the following minimum amount of automotive liability insurance: the greater of (1) a combined single limit of Three Hundred Thousand Dollars ($ 300,000); or (2) all the insurance coverage and/or limits carried by or available to Contractor. Said insurance shall cover bodily injury, death and property damage for all owned, non-owned and hired vehicles and be written on an occurrence basis.
d. Any insurance proceeds in excess of or broader than the minimum required coverage and/or minimum required limits which are applicable to a given loss shall be available to City. No representation is made that the minimum insurance requirements of this Agreement are sufficient to cover the obligations of Contractor under this Agreement.
e. Each policy of general liability and automotive liability shall provide that City, its officers, officials, agents, and employees are declared to be additional insureds under the terms of the policy, but only with res pect to the work performed by Contractor under this Agreement. A policy endorsement to that effect shall be provided to City along with the certificate of insurance. In lieu of an endorsement, City will accept a copy of the policy(ies) which evidences that City is an additional insured as a contracting party. The minimum coverage required by Subsection 18.b and c, above, shall apply to City as an additional insured. Any umbrella liability insurance that is provided as part of the general or automobile liability minimums set forth herein shall be maintained for the duration of the Agreement.
f. Contractor shall maintain during the life of this Agreement professional liability insurance covering errors and omissions arising out of the performance of this Agreement with a minimum limit of One Million Dollars ($1,000,000) per claim. Contractor agrees to keep such policy in force and effect for at least five (5) years from the date of completion of this Agreement.
7 g. The insurance policies maintained by Contractor shall be primary insurance and no insurance held or owned by City shall be called upon to cover any loss under the policy.
Contractor will determine its own needs in procurement of insurance to cover liabilities other than as stated above.
h. Before Contractor performs any work or prepares or delivers any materials, Contractor shall furnish certificates of insurance and endorsements, as required by City, evidencing the aforementioned minimum insurance coverages on forms acceptable to City, which shall provide that the insurance in force will not be canceled or allowed to lapse without at least ten (10) days’ prior written notice to City.
i. Except for professional liability insurance coverage that may be required by this Agreement, all insurance maintained by Contractor shall be issued by companies admitted to conduct the pertinent line of insurance business in California and having a rating of Grade A or better and Class VII or better by the latest edition of Best Key Rating Guide. In the case of professional liability insurance coverage, such coverage shall be issued by companies either licensed or admitted to conduct business in California so long as such insurer pos sesses the aforementioned Best rating.
j Contractor shall immediately notify City if any required insurance lapses or is otherwise modified and cease performance of this Agreement unless otherwise directed by City.
In such a case, City may procure insurance or self-insure the risk and charge Contractor for such costs and a ny and all damages resulting therefrom, by way of set -off from any sums owed Contractor.
k. Contractor agrees that in the event of loss due to any of the perils for which it has agreed to provide insurance, Contractor shall look solely to its insurance for recovery.
Contractor hereby grants to City, on behalf of any insurer providing insurance to either Contractor or City with respect to the services of Contractor herein, a waiver of any right to subrogation which any such insurer may acquire against City by virtue of the payment of any loss under such insurance.
l. Contractor shall include all subcontractors, if any, as insureds under its policies or shall furnish separate certificates and endorsements for each subcontractor to City for review and approval. All coverages for subcontractors shall be subject to all of the requirements stated herein.
19. Termination. City may for any reason terminate this Agreeme nt by giving Contractor not less than five (5) days’ written notice of intent to terminate. Upon receipt of such notice, Contractor shall immediately cease work, unless the notice from City provides otherwise.
Upon the termination of this Agreement, City shall pay Contractor for services satisfactorily provided and all allowable reimbursements incurred to the date of termination in compliance with this Agreement, unless termination by City shall be for cause, in which event City may withhold any disputed compensation. City shall not be liable for any claim of lost profits.
8 20. Maintenance and Inspection of Records. In accordance with generally accepted accounting principles, Contractor and its subcontractors shall maintain reasonably full and complete books, documents, papers, accounting records, and other information (collectively, the “records”) pertaining to the costs of and completion of services performed under this Agreement.
City and its authorized representatives shall have access to and the right to audit and reproduce any of Contractor's records regarding the services provided under this Agreement. Contractor shall maintain all such records for a period of at least three (3) years after termination or completion of this Agreement. Contractor agrees to make available all such records for inspection or audit at its offices during normal business hours and upon three (3) days’ notice from City, and copies thereof shall be furnished if requested.
21. Compliance with all Laws/Immigration Laws.
a. Contractor shall be knowledgeable of and comply with all local, state and federal laws which may apply to the performance of this Agreement.
b. If the work provided for in this Agreement constitutes a “public works,” as that term is defined in Section 1720 of the California Labor Code, for which prevailing wages must be paid, to the extent Contractor’s employees will perform any work that falls within any of the classifications for which the Department of Labor Relations of the State of California promulgates prevailing wage determinations, Contractor hereby agrees that it, and any subcontractor under it, shall pay not less than the specified prevailing ra tes of wages to all such workers . The general prevailing wage determinations for c rafts can be located on the w ebsite of the Department of Industrial Relations (www.dir.ca.gov/DLSR). Additionally, to perform work under this Contract, Contractor must meet all State registration requirements and criteria, including project compliance monitoring.
c. Contractor represents and warrants that it:
(1) Has complied and shall at all times during the term of this Agreement comply, in all respects, with all immigration laws, regulations, statutes, rules, codes, and orders, including, without limitation, the Immigration Reform and Control Act of 1986 (IRCA); and
(2) Has not and will not knowingly employ any individual to perform services under this Agreement who is ineligible to work in the United States or under the terms of this Agreement; and
(3) Has properly maintained, and shall at all times during the term of this Agreement properly maintain, all related employment documentation records including, without limitation, the completion and maintenance of the Form I -9 for each of Contractor’s employees; and
(4) Has responded, and shall at all times during the term of this Agreement respond, in a timely fashion to any government inspection requests relating to immigration law compliance and/or Form I -9 compliance and/or worksite enforcement by the Department of Homeland Security, the Department of Labor, or the Social Security Administration.
d. Contractor shall require all subcontractors or subconsultants to make the same representations and warranties as set forth in Subsection 21.c. 9 e. Contractor shall, upon request of City, provide a list of all employees working under this Agreement and shall provide, to the reasonable satisfaction of City, verification that all such employees are eligible to work in the United States. All costs associated with such verification shall be borne by Contractor. Once such request has been made, Contractor may not change employees working under this Agreement without written notice to City, accompanied by the verification required herein for such employees.
f. Contractor shall require all subcontractors or sub-consultants to make the same verification as set forth in Subsection 21.e.
g. If Contractor or subcontractor knowingly employs an employee providing work under this Agreement who is not authorized to work in the United States, and/or fails to follow federal laws to determine the status of such employee, that shall constitute a material breach of this Agreement and may be cause for immediate termination of this Agreement by City.
h. Contractor agrees to indemnify and hold City, its officers, officials, agents and employees harmless for, of and from any loss, including but not limited to fines, penalties and corrective measures City may sustain by reason of Contractor's failure to comply with said laws, rules and regulations in connection with the performance of this Agreement.
22. Governing Law and Venue. This Agreement shall be construed in accordance with and governed by the laws of the State of California and Contractor agrees to submit to the jurisdiction of California courts. Venue for any dispute arising under this Agreement shall be in Orange County, California.
23. Integration. This Agreement constitutes the entire agreement of the parties. No other agreement, oral or written, pertaining to the work to be performed under this Agreement shall be of any force or effect unless it is in writing an d signed by both parties. Any work performed which is inconsistent with or in violation of the provisions of this Agree ment shall not be compensated.
24. Notice. Except as otherwise provided herein, all notices required under this Agreement shall be in writing and delivered personally , by e -mail, or by first class U.S. mail, postage prepaid, to each party at the address listed below. Either party may change the notice address by notifying the other party in writing. Notices shall be deemed received upon receipt of same or within three (3) days of deposit in the U.S. Mail, whichever is earlier. Notices sent by e- mail shall be deemed received on the date of the e-mail transmission.
“CONTRACTOR” “CITY”
Darren P. Doerschel City of Orange
2307 32nd Street #3 300 E. Chapman Avenue
Santa Monica, CA 90405 Orange, CA 92866-1591
Attn.: Darren Doerschel Attn.: Will Kolbow
Telephone: (310) 350-8399 Telephone: (714) 744-2235 E-Mail: [email protected] E-Mail: [email protected] 10 25. Counterparts. This Agreement may be executed in one or more counterparts, each of which shall be deemed an original, but all of which together shall constitute one and the same instrument. Signatures transmitted via facsimile and electronic mail shall have the same effect as original signatures.
IN WITNESS of this Agreement, the parties have entered into this Agreement as of the year and day first above written.
“CONTRACTOR” “CITY”
DARREN DOERSCHEL, a sole proprietor CITY OF ORANGE, a municipal corporation
*By: By:
Printed Name: Mark A. Murphy, Mayor
Title:
ATTEST:
Pamela Coleman, City Clerk
APPROVED AS TO FORM:
Mary E. Binning
Senior Assistant City Attorney
EXHIBIT “A”
SCOPE OF SERVICES
[Beneath this sheet.]
Darren P. Doerschel, Systems Integration Consultant
2307 32nd Street #3 Santa Monica, CA 90405 VOICE: 310.350.8399 EMAIL: [email protected]
June 2nd, 2022
To: Mike Dering
Project Manager
Information Technology, City of Orange
Re: City of Orange, Civic Meeting TV/AV Production Personnel Support, AV Preparation and Systems Maintenance Support
Mr. Dering:
Thank you for allowing me the opportunity to provide you a proposal for ongoing TV and AV production personnel support at each of the civic meetings including the City Council meetings, Planning Commission meetings and the Design Review Committee meetings. Additionally, the City is need of continued technical support related to the newly installed AV Systems and TV Systems supporti ng the Council Chamber operations and can be categorized as infrastructure and systems maintenance support.
TV Production and AV Functionality Support
The TV/AV production personnel to attend each meeting will provide technical oversight and support of the ongoing operations principally ran the by the Chapman students as well as a lead role in TV/AV production during the Design Review Committee (DRC) meetings and others as requested by the City. We will take the lead role in TV/AV production responsibilities and require a higher level of effort and operational support.
Additionally, a new er AV test and preparation service role has been requested whereb y crew arrive earlier, up to 2 hours before the meetings, to go through a check list of Audio Visual device and systems performance testing.
Infrastructure and Systems Maintenance Support
The major systems to be reviewed and targeted for maintenance suppor t include the On -Air Playback Automation System, the Camera Control and Robotics System, the Graphics and Character Generator System, the Video Production Switcher, the Sound Reinforcement System, the AV Control System, the Video and Audio Routing Systems, the Distribution and Monitoring Systems and any other technically related subsystems.
Proposal
The following services to be provided are based on a minimum number of hours and, based on information provided, estimated average hours of onsite TV/AV production support. The TV/AV production personnel will arrive onsite at least 2 hours before the start time of the meetings . TV Maintenance is based on quarterly ser vice and an estimate of as -needed hours based on the life cycle of equipment and MTF estimates on regressive functionality projections.
Minimum Time Estimates
Estimates are based on the accuracy of previous projections for these services fo r the City of Orange. F ull hours of service in the subtotals i s supported for appropriate budgetary purposes since several factors, unforeseen or otherwise requested, are necessary in the projections.
<continued below>
Darren P. Doerschel, Systems Integration Consultant
2307 32nd Street #3 Santa Monica, CA 90405 VOICE: 310.350.8399 EMAIL: [email protected]
TV Production, Oversite, and AV Testing and Cost Estimates $125 per hour cost basis
These are only estimates based on the current understanding of the City’s scheduling needs. The cost proposal includes minimum hours to carry out services, however no minimum hours will be billed to the City if no services are rendered onsite.
Please contact me with any changes you wish to make regarding this proposal. Thank you for the opportunity, I look forward to assisting the City of Orange with their AV and TV Production operation al needs and maintaining the TV Broadcast Systems as necessary.
Sincerely,
Darren P. Doerschel
Systems Integration Consultant
310.350.8399
2307 32
nd Street #3
Santa Monica CA 90405
Description of Services Minimum Units Projected Max. Projected Per/month Costs City Council Meeting TV/AV Personnel Support 4 Hours 6 Hours 1500 (2 per/month) Planning Commission Meetings TV/AV Personnel Support 4 Hours 5 Hours 1250 (2 per/month) Design Review Committee Meetings TV/AV Personnel Support 4 Hours 6 Hours 1500 (2 per/month) Quarterly Meetings (Traffic, Parks for AV Prep and Monitoring) 3 Hours/per mtg 8 Hours/per Qtr. 250 per month (.25) Projected Total Monthly Costs $4500
Annual Projected Costs $54,000
Quarterly Maintenance Cost Estimates
Description of Services on Quarterly Basis Quarterly Units Annual Units Quarterly Assessment, Training, Maintenance Support 25 hours 100 Onsite As-Needed Evaluation, Repair, Phone Support (Floating) 15 hours 60 Annual Hours 160
Annual Estimate $20,000
COMBINED ANNUAL ESTIMATE (not-to-exceed) $74,000