EXHIBIT B
TRACT MAP OF THE PROPOSED ANNEXATION TERRITORY
CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2007-1
(PUBLIC SAFETY SERVICES)
ANNEXATION NO. 4
LATITUDE 61, TRACT # 38776
Item 1F - Page 10
Item 1F - Page 11
H()1/II(( PUfU Oil OMR Off1CER COMPtBJIC 1HS ~
r JHC wmrr or me N:MXMt. H SIGNCD me DOaJIIDIT ro MIDI
11IS CEN~ ~ MD HOT 11£ JRlRHRJU,'fSS, ACCUW:'Y, OR
soor Of CAtifntNr'A
- Of 'RwrRs iaE
0/I Jf/Nff jlf' 202Hf/!J/1£ l/£ /Jt/JtA, !, Autlet:
• IKJTNrr PIJ8IX. P£IISOll'UY - a,;,, 1>. Mj1Aa1111it.M ""' -10 IE ON lHf MSIS Of S411STACJarr OW1«X 70 8£ 11£ P£RSOH(SJ MA)Sl' NM£(!) 1Sftll('smsa&DT01H!lfflHWIIS1IMIEHT'NIJM':l<M:1fU'DCt.10.11£1H,,IT ~ EXlW/fD 11£ SIii£ II HIS/!ISl/!NII'! "11NORIZID CAPM>n; (&) NID lll'1 f/Y IIS/ll!l1/l!B! ~ OIi n,,: IIIS1IMIEHr.,, l'f1ISlll(sl, 0/11!/f £JITl1'f I/Pal ~ = ~~~~,::; ~1£ Of C4UfORM4 ffl.\T
7HC roRmOIN'J PNWiRN'H IS mtJC MJ CQlillf£C7:
~
HNI) NlO MJCl4I. SDL
'114, A 41,,-/v, (sr,,J
NO PU8UC II AND FOR SN() S7AJE
(WA s. Auiun
v-rm"""'
IIY Pfl/HOl'N. PIia Of IIUSll£SS IS " TbtJEN(i(/,! COONrY.
IIY c:<WS90H EXP1R£S 1-/Atw 31,.1.0'U,
IN THE CITY OF PALM SPRINGS, COUNTY OF RIVERSIDE, STATE OF CALIFORNIA OF'/ SHEETS . TRACT NO. 38776
GOVERNMENT LOT 154, BEING THEE 1/2 OF THE NE 1/4 OF THE SW 1/4 OF THE NE 1/4 OF SECTION 14, TOWNSHIP 4 SOUTH, RANGE 4 EAST, S.B.M.
FUD 1HIS 11.INBOOK OfllAPS ,,..
AT JP£ REtKlll' Of THE 1MW. ~ Of AGtK ClilJOO'E
NM> Of r.NU.1A NJW1s. A rmERAilY R£COCHll£D IHDWl 7REE'. ""r;,1/4.,, -4=--FOR LEASE AND CONDOMINIUM PURPOSES
AH€1J]~$; MARCH 2024
PmR ..,_
Ct1JKTY J.$S£.'SSllff-ruRl(-RE'CQ!IO'
MffMIENrHO.~-oa.a,a?'f FI£~
SVf/DMS/0// ..-a If(: c1t1CA-Go :fr'.IllfcoM~~y NOTARY ACKNOWLEDGMENT A HOTJRr PUil£ OR OHR Of1lD QWPl£JN1 MS ~1£ 'r9l16 "-1.Y TH£ KJENmY or DE HlMXW. IM1 SICl£1J ff' OOCV&IOff TO WHICH THIS Cf1l1f10U£ ,s AJTACHED, JHO ,m ff ~ NXHIN:r, OR WD1Y Of TH4T ~-
SW, Of
A NOT/Rf PUBVC OR OHR OfflCER COll'l£JWG rJfS CfRl'f'EIUF w»fES OM.I" DE mmrt ~~ '==. =:. ~ ~ ":': ~rr IS A~ NID
STJJ£0f
"""""Of g; &f.i els
OH if40e., ~.zoB':f 202f l3CRR llF r<'A«n H;:AMef'\
A HIJTN('( W ~y N'PfNIEl) <:!)o,,e,i O J' Gswow!,S tl9fO PRCM"D n> Mt OIi 11£ BASIS Of S<m>'ACRIIY """7laC JD BE I!£ PfRSt//l(Bt' - ~ ~Mt """"""' JD 11£-flSTRI.OlfNTN/0""""""1'0 JUI/£ IHU'~~..mf! S<IICIH :,~ ~ ~ ~ ~IHU'sa:, ~ ~,.g:.. l!/f=
111£ IHSliiUll£NT.
1 a,nrr lHJf.7f f'OWJY or PmtWr fMDER me LQS or M swr OF COtllfHM nw me FOPS/()I/K)P1IIN/IIN'H/$1111£NIDCORR£Cr.
M7h'ESS '1Y H4ND AND OOD4t. S£M..
~~
IKJTNrr Pf.JIU; IN N¥J FOR SW SWE'
(SDI.)
~f;;£ ~~_;~.,,, il'<"ii>tr ~97'f'II,
&rfffKIPN.PlACCOFBUSMSSISIH ~1'C(Sidct cowrr.
&rf OOU1,CS.S01 ~JMY:AO:?,l'-t'•cato
8/GNA TURE OM/SSfONS
PfJRSUWr TO S£C110N dUJa OF 1H£ SV80MSIOH W !CT. n£ SICIMJVR£s ()f m£ FW.on«: OIIHDlS Of EM£llENTS Nm/OR OTHER IHT£flES1' ~ 8WI OlJl11EO:
RIQtr or w '1lANrm 10 1HE arr OF PMM ~ iJIPRO'ttV JWVNrr s. ,,n, PtJRSUWr ro 1H£ IQ Of flBRtMRY 05, IHB (62 STAT, 17). ooctJIIOff l«JllBER J7'00J91PS.
RJCHr OF 14Y CIW(1fJ) TO 111£ arr OF P/llJI SffllHCS, iffllO\,fD SEP1Dlf1ER i-ft l17J, IVlSUNiT TO rn£ N:1 OF mwtM'r' 05. 1948 (62 ffir. 11). DOCWENT M.1111D' JJ500472PS. 11/CHTOfllllYCIWIIUJ 10 11/Ectr/ Of PMJlsmHCS, """"1,U>- 8, :mt Pf.fiStW(( JD 'DE ACT OF F£IJRUmf 0$. 1'48 ('2 STAT. 17). OOCIJ1'CH1' NWIBER .fffl)HOOU.
SURVEYOR'S STATEMENT
1RIBAL SECRETARY STATEMENT
t S'.'M4 rt. S4WtI. JRIB4l SIDIIJN« Of DE AGtM CW£NTE &WO OF CIJlW INDi,W$, A FEDElWLY R£""1HlED #OW JR&:. HCREBI' COOfY 1H4T SW lRIMl. co,,a_ AT r1S RmVLM AEC11HC HEW OH 11£ I 11H MY fT ~ 2024, Dtl.l" APPRfMD FM. W HO. J6176. lH! rDfflJM: UAP \IIS ll'PRfM1J EN Tl£ JJillW. COUf«I. AT IFS RfCllNl JIE!1M:
htlD OH M 2JRD LMY OF J/IIIUNrf, 20'/f.
~A,~iLa.-CK--
TAX COLLECTOR'S CERTIF1CATE
I l£R£BY CfRTfY 1H4T NXXWJHG 10 1fE R£aRIS OF 1HS 0'71Ct AS OF 1'fS ~ 1h'CRE' ME NO lEHS KJAllSf TH£ PROPERJY !ltMH OH nE tmlH 1111' FM LWPM:> STAJE; COLWJY, ut.WICfW. M LO<A TAIES OR Sl'£CIA/. """"""1l OOUIC!!I> AS T"fl'S" $"0 :0• .. ~ ,,,,. .,, ~rmn, .......
CIIJl(T'( W o:>U.£tD TtlS CfRTIFlCA.TION EXCWDts ANY
sumr""':~~NOT
JJOJOJ-n, Oll/ll/2W4
Item 1F - Page 12
IN THE CITY OF PALM SPRINGS, COUNTY OF RIVERSIDE, STATE OF CALIFORNIA TRACT NO. 38776
GOVERNMENT LOT 154, BEING THEE 1/2 OF THE NE 1/4 OF THE SW 1/4 OF THE NE 1/4 OF SECTION 14, TOWNSHIP 4 SOUTH, RANGE 4 EAST, S.8.M.
FOR LEASE AND CONDOMINIUM PURPOSES
AH€1J!:i=$; . MARCH 2024
Item 1F - Page 13
LU 1eo
- sc,u:, 1'• io'
P.M.XNT
SJ/75-77
IN THE CITY OF PALM SPRINGS, COUNTY OF RIVERSIDE, STATE OF CALIFORNIA TRACT NO. 38776
GOVERNMENT LOT 154, BEING THEE 1/2 OF THE NE 1/4 OF THE SW 1./4 OF THE NE 1/4 OF SECTION 14, TOWNSHIP 4 SOUTH, RANGE 4 EAST, S.8.M.
FOR LEASE AND CONDOMINIUM PURPOSES
AH~•JfFf MARCH 2024
BOUNDARY MAP
LOT1 ~, i -
~is
LOT1''
LOT2
-LOTW- ti ---1:;
LOT3
~, ..
IUl 109
I
1MCT1,.,
U1T1
SHEET J OF 4 SHEETS
BASIS OF BEARINGS
D<e<!ISOf-tmNS-ffHCOODIIKO,
- Ql'f,ot ..,_ 1'1/11 lfNI HOO'Ol'St ....
SURVEYOR'S NOTES1
·----11$-
• l()ICUUIOIM)l ' ll, .,,,IIASIIC"-U.U.-,ot .... ,.,,,.. 0 N>COES RT-.,, ffNlfD U 011¥,
Jff MflllNG 140 U ,,_. IIIHC 'lf#tJIQ#R IU
lm('CB Silt' Ulf UC II I.O er no,r LOI' a:aias
IU"'lNG'lll:USlllrflJIIPOfa«J<llllOlfl
-AIIUIIVl/1«-
( ) N>COES - 0<1A ,at ll UV,7,
() --O<IAl'OIU. ISlt,.
(-..UCOOUUC
IC --181 MIC«$ .W. NO N'
HS lll4CI'- tm 1-.\ -NG UJJDDtm 'A'
-"'--HS--••1.oss-.
EASEMENT NOTES:
<I> =:-l"'~~~~,:.=:w
(fl...,, 11). 1J1JOND11 ,._,. mou11'S.
(Z) ~~ 7~':' ~~ ~..w:o,,.. (fl ml 11). _ ,,,,,_ moo,n,s QI _o,..,._,_,fftlfrO,NIJI-
_,.,.... -a,NIQOf-«l lt4l(R SW:11). ____ L
Item 1F - Page 14
I a
I ~
11:: a
~, ;
HO
CRAPtlCSCN.,01 ... I/IO.
IN THE CITY OF PALM SPRINGS, COUNTY OF RIVERSIDE, STATE OF CAUFORNIA TRACT NO. 38776
GOVERNMENT LOT 154, BEING THEE 1/2 OF THE NE l/4 OF THE SW l/4 OF THE NE 1/4 OF SECTION .l4, TOWNSHIP 4 SOUTH, RANGE 4 EAST, S.B.M. 'FOR LEASE AND CONDOMINIUM PURPOSES
At.!~l)J~f ' MARCH2024
LOT1·
1.668 AC.
IIIOC'OfV-."°1.M'
LODI' J,'70 IC. N»'Of~YmJf
•
,,,..,,
_...,...,.
IIA
IIIACYIIIII
IDTI
. -......
..,,.'Ir.Ar
LOT2
0.671 AC.
.-Otlt"lrMJ,,$1'
P!!l''Y.: ,,..,. · LQI'.A' , .110 IC.
.. ,....JU.#
LOT3
IIA,_
'IRACTII.,
IDTI
~
'!5 I t " . p ~ ~~
3 • 0 !l ,a:: .. _
1~
..,
SHEET 4 OF 4 SHEETS
LN!TJU
""I """' -" -....,. ....
" ..., _,,,.,
u . ., .........
" -..,,... ..
" ,.,,, _,, .. ,., _,.
1l j
ii~
., ""' ..........
,; ,.,,
--,.. ""' _.., ..
"' -..........
'" ..... ..........
'" ,.,., _ ..
UJ ..... __,. ..
'" -_, ..
"'
1111' MnlW'Y
,. ,.,..
-· "'
14.14' ..,,,..,, , . ..,, ..,,.... ..
"' -.....,..,,
ti-:1f:i """°'" _, -
...,, ....
" , .... ...,
-Q ..... ..,,,
-., ...... ..... __,.,
EXHIBIT C
LIST OF PARTICIPATING ASSESSOR’S PARCELS
CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2007-1
(PUBLIC SAFETY SERVICES)
ANNEXATION NO. 4
LATITUDE 61, TRACT #38776
APN Acres Landowner
508-070-056 1.67 USA BIA
508-070-057 0.67 USA BIA
508-070-058 0.53 USA BIA
508-070-059 0.03 USA BIA
508-070-060 0.07 USA BIA
508-070-061 0.10 USA BIA
508-070-062 1.17 USA BIA
Item 1F - Page 15
1 2
EXHIBIT D
RATE AND METHOD OF APPORTIONMENT
CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2007-1
(PUBLIC SAFETY SERVICES)
A Special Tax of Community Facilities District No. 2007-1 (Public Safety Services) of the City of Palm Springs (the "District") shall be levied on all Assessor's Parcels in the District and collected each Fiscal Year commencing in Fiscal Year 2008-09 in an amount determined by the City through the application of the rate and method of apportionment of the Special Tax set forth below. All of the real property in the District, unless exempted by law or by the provisions hereof, shall be taxed for the purposes, to the extent and in the manner herein provided.
A. DEFINITIONS
The terms hereinafter set forth have the following meanings:
"Act" means the Mello-Roos Community Facilities Act of 1982, being Chapter 2.5, Part 1, Division 2 of Title 5 of the Government Code of the State of California, as amended, which authorizes the establishment of the District to finance: a) police protection services, and b) fire protection and suppression services, and life safety services including but not limited to ambulance and paramedic services.
"Administrative Expenses" means the actual or estimated costs incurred by the City as administrator of the District to determine, levy and collect the Special Taxes, including the proportionate amount of the salaries and benefits of City employees whose duties are directly related to administration of the District and the fees of consultants, legal counsel, the costs of collecting installments of the Special Taxes upon the general tax rolls, preparation of required reports; and any other costs required to a dminister the District as determined by the City.
"Annual Escalation Factor" means the greater of the increase in the annual percentage change of the All Urban Consumers Consumer Price Index (CPI) or the percent increase of salaries and benefits for public safety employees as stated in the Memorandum of Understanding for the fiscal year of the Special Tax. The annual CPI used shall be for the area of Los Angeles -Riverside-Orange County, CA as reflected in the then -current April update. The annual CPI used shall be as determined by the United States Department of Labor, Bureau of Labor Statistics, and may be obtained through the California Division of Labor Statistics and Research (www.dir.ca.gov/dlsr). If the foregoing index is not available, the District Administrator shall select a reasonably comparable index.
Item 1F - Page 16
1 2
"Assessor's Parcel" means a lot or parcel shown in an Assessor's Parcel Map with an assigned assessor's parcel number.
"Assessor's Parcel Map" means an official map of the Assessor of the County designating parcels by assessor's parcel number.
"Base Year" means Fiscal Year ending June 30, 2008.
"BIA" means the Bureau of Indian Affairs within the Department of the Interior and any tribe acting on behalf of the BIA
"City" means the City of Palm Springs.
"Council" means the City Council of the City of Palm Springs, acting as the legislative body of the District.
"County" means the County of Riverside, California.
"Developed Multi -Family Residence" means an Assessor's Parcel of Developed Property for which a building permit has been issued for purposes of constructing a residential structure consisting of more than one residential Dwelling Unit which share common walls, including, but not limited to, duplexes, triplexes, town homes, condominiums, and apartment units.
"Developed Property" means all Taxable Property, exclusive of Property Owner Association Property, Non-Residential Property, or Public Property, for which a building permit was issued prior to May 1 st preceding the Fiscal Year in which the Special Tax is being levied.
"Developed Single -Family Residence" means an Assessor's Parcel of Developed Property for which a building permit(s) has been issued for purposes of constructing one single-family residential Dwelling Unit.
"District Administrator" means an official of the City, or designee thereof, responsible for determining the Special Tax Requirement and providing for the levy and collection of the Special Taxes.
"District" means Community Facilities District No. 2007-1 (Public Safety Services) of the City of Palm Springs.
"Dwelling Unit" means any separate residential unit in which a person or persons may live, which includes provisions for sleeping, cooking and sanitation, and is not considered to be for commercial or industrial use.
"Fiscal Year" means the period starting July 1 and ending on the following June 30.
Item 1F - Page 17
1 2
"Government Land" means an area of land, or interest therein, in which the Surface Estate is owned by the United States of America and is administered by the BIA.
"Indian Land" means an area of land in which interest in the Surface Estate is owned by a tribe or individual Indian, including but not limited to Government Land or Tribal Land.
"Interest" means an ownership right to the Surface Estate of Indian Land that may be unlimited or uncertain in duration.
"Land Use Class" means any of the classes listed in Table 1.
"Lease" means a written agreement between the Government or Indian landowner(s) and the Lessee, whereby the Lessee is granted a right to possession of Government or Indian Land, for a specified purpose and duration.
"Leasehold Interest" means the Lessee's independent and exclusive right to possession of, or claim to, the property under the terms and conditions specified in the Lease or Sublease, For purposes of this definition, Leasehold Interest is also referred to as possessory interest within the County.
"Lessee" means a person or entity who has acquired a legal right of possession to Indian Land by a Lease or Permit as defined in Section A, for which said person or entity holds a possessory interest in the property. For purpose of this definition, the Lessee may also be referred to as the tenant.
"Maximum Special Tax" means the maximum Special Tax, determined in accordance with Section C below that can be levied in the District in any Fiscal Year on any Assessor's Parcel which is classified as either a Single -Family Residence or a Multi Family Residence as defined in Section A.
"Non-Residential Property" means an Assessors' Parcel for which a building permit(s) has been issued for a non-residential used and does not contain any residential Dwelling Units as defined in Section A.
"Permit" means a written agreement between the Indian Landowner(s) and the applicant for the permit, also referred to as a permittee, whereby the permittee is granted a revocable privilege to use Indian Land or Government Land, for a specified purpose.
"Property Owner Association Property" means any property within the boundaries of the District that is owned by, or irrevocably dedicated as indicated in an instrument recorded with the County Recorder to a property owner association, including any master or sub-association.
"Proportionately" means in a manner such that the ratio of the actual Special Tax levied to the Maximum Special Tax is equal for all Assessor's Parcels within classified as Developed Property.
Item 1F - Page 18
"Public Property" means any property within the boundaries of the District that is, at the time of the District formation or at the time of an annexation, expected to be used for rights-of-way, parks, schools or any other public purpose and is owned by or irrevocably offered for dedication to the federal government, the State, the County, the City or any other public agency.
"Public Safety Service Costs" means the estimated and reasonable costs of providing police services and fire protection and suppression services and life safety services, including but not limited to (i) the costs of contracting services, (ii) equipment, vehicles, ambulance, and paramedics, fire apparatus, supplies, (iii) the salaries and benefits oi City staff that directly provide police services and fire protection and suppression services and life safely services, respectively, and (iv) City overhead costs associated with providing such services within the District. The Special Tax provides only partial funding for police, fire and life safely services.
"Special Tax" means the Special Tax to be levied in each Fiscal Year on each Assessor's Parcel of Developed Property to fund the Special Tax Requirement, and shall include Special Taxes levied or to be levied under Sections C and D, below.
"Special Tax Requirement" means that amount required in any Fiscal Year for the District to: (i) pay for Public Safety Service Costs; (ii) pay reasonable Administrative Expenses; (iii) pay any amounts required to establish or replenish any reserve funds; and (iv) pay for reasonably anticipated delinquent Special Taxes based on the delinquency rate for Special Taxes levied in the previous Fiscal Year; less any surplus of funds available from the previous Fiscal Year's Special Tax levy.
"State" means the State of California.
"Sublease" means written agreement by which the Lessee grants to an individual or entity a right to possession no greater than that held by the Lessee under the Lease.
"Surface Estate" means on ownership of the surface of a particular area of land by any person or persons who holds record title to the surface of the land, and which is identified by the ownership records of the County in which the real property is located.
"Tax-Exempt Property" means an Assessor's Parcel not subject to the Special Tax.
Tax-Exempt Property includes: (i) Public Property, (ii) Property Owner Association Property, (iii) Non-Residential Property, and (iv) property designated by the City or District Administrator as Tax-Exempt Property.
"Tribal Land" means the Surface Estate of land or any interest therein held by the United States of America in trust for a tribe, band, community, group or pueblo of Indians, and land that is held by a tribe, band, community, group or pueblo of Indians, subject to federal restrictions against alienation or encumbrance, and includes such land reserved for BIA administrative purposes when it is not immediately needed for such purposes.
Item 1F - Page 19
B. ASSIGNMENT TO LAND USE CATEGORIES
Each Fiscal Year using the definitions above, all property within the District shall be classified as either Developed Property or Tax -Exempt Property. Developed Property shall be further classified as Developed Single -Family Residence or Developed Multi Family Residence. Commencing with the Base Year and for eac h subsequent Fiscal Year, all Developed Property shall be subject to Special Taxes pursuant to Sections C and D below.
C. MAXIMUM SPECIAL TAX RATE
1. Developed Property
TABLE 1
Maximum Special Tax for Developed Property
Community Facilities District No. 2007-1
(Public Safety Services)
Land Use Class Description Maximum
Special Tax
1 Developed Single-Family
Residence
$362.24 per Dwelling
Unit
2 Developed Multi-Family
Residence
$305.32 per Dwelling
Unit
On each July 1 following the Base Year (i.e., July 1, 2008), the Maximum Special Tax Rates in Table 1 shall be increased in accordance with the Annual Escalation Factor. Once the Maximum Special Tax per Dwelling Unit is equal to $500 per Dwelling Unit, no further Annual Escalation Factor shall be applied and the Maximum Special Tax per Dwelling Unit shall not exceed $500.
2. Tax-Exempt Property
No Special Tax shall be levied on Tax-Exempt Property.
3. Multiple Land Use Classes
In some instances, an Assessor's Parcel may contain more than one Land Use Class. The Maximum Special Tax levied on an Assessor's Parcel shall be the sum of the Maximum Special Tax levies that can be imposed on all Land Use Classes located on that Assessor's Parcel.
D. METHOD OF APPORTIONMENT OF THE SPECIAL TAX
Commencing with Fiscal Year 2008-09, and for each subsequent Fiscal Year, the District Administrator shall calculate the Special Tax Requirement based on the definitions in Item 1F - Page 20
Section A and levy the Special Tax upon each Dwelling Unit of the Leasehold Interest (also known as the "possessory interest") as follows, until the amount of the Special Tax levied equals the Special Tax Requirement. The Special Tax shall be levied each Fiscal Year upon the Leasehold Interest of each Assessor's Parcel of Developed Property Proportionately between Developed Single -Family Residential Dwelling Units and Developed Multi-Family Residential Dwelling Units up to 100% of the applicable Maximum Special Tax.
E. APPEALS
Any tax payer that believes that the amount of the Special Tax assigned to an Assessor's Parcel is in error may file a written notice with the District Administrator appealing the levy of the Special Tax. This notice is required to be filed with the District Administrator during the Fiscal Year the error is believed to have occurred. The District Administrator or designee will then promptly review the appeal and, if necessary, meet with the taxpayer.
If the District Administrator verifies that the tax should be changed the Special Tax levy shall be corrected and, if applicable in any case, an adjustment shall be made.
F. EXEMPTIONS
1. Assessor Parcels classified as Developed Property
Developed Properties which annually meet one or more of the following standards shall be exempt from payment of the Special Tax:
a. A Residential Property consisting of one or two person(s) collectively earning $15,300 or less gross income per year, upon complying with procedures to establish such exemption, or
b. A Residential Property consisting of three persons collectively earning $17,900 or less gross income per year, upon complying with procedures to establish such exemption, or
c. A Residential Property which qualifies for either the Low Income Rate Assistance (LIRA) exemption for electrical or gas services or the Lifeline exemption for telephone services.
The City is authorized and directed to promulgate administrative rules and procedures for verification of eligibility for the exemptions referred to in section F.
G. MANNER OF COLLECTION
Special Tax as levied pursuant to Section D above shall be collected in the same manner and at the same time as ordinary ad valorem property taxes; provided, however, that the District Administrator may directly bill the Special Tax, many collect Special T axes at a different time or in a different manner if necessary to meet the financial obligations of the District or as otherwise determined appropriate by the District Administrator.
Item 1F - Page 21
H. TERM OF SPECIAL TAX
Every Five years after the establishment of the District, the City Council may reexamine, if deemed necessary by City Council, the necessity of the continuance of the Special Tax through the preparation of a Fiscal Impact Analysis, otherwise the Special Tax shall be levied in perpetuity.
Item 1F - Page 22
EXHIBIT E
NOTICE OF PUBLIC HEARING
Notice is hereby given that the City Council of the City of Palm Springs will conduct a public hearing on Wednesday, May 14, 2025, at 5:30 p.m. or as soon thereafter as the matter may be heard, in the City Council Chambers located at 3200 East Tahquitz Canyon Way, Palm Springs, California, 92262, to consider the following:
CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2007-1
(PUBLIC SAFETY SERVICES)
ANNEXATION NO. 4
LATITUDE 61, TRACT #38776
On March 27, 2025 , the City Council, as the legislative body for the District, adopted a resolution entitled " A Resolution Of The City Council Of The City Of Palm Springs, California, Declaring Its Intention To Annex Territory Into A Community Facilities District To Authorize The Levy Of Special Taxes " (the "ROI"). Pursuant to the ROI, the City Council determined that the public convenience and necessity require that certain territory, as more particularly described in the ROI, be annexed to the existing District, all as provided in the Mello -Roos Community Facilities Act of 1982 (Sections 53311 and following, California Government Code) (the "Act"). Reference is hereby made to the ROI, on file with the City Clerk of the City for further particulars. The following is a summary of the provisions of the ROI.
In the ROI, the City Council declared its intention to annex territory into Community Facilities District No. 2007-1 (Public Safety Services) (the "District"). The area proposed to be annexed to the District is as shown on Annexation Map No. 4, on file with the City Clerk, and identified in Exhibit A of the ROI. The District shall fund police services, fire protection and suppression services, and life safety services. It is presently intended that the services will be provided, without preference or priority, to the existing territory in the District and the territory proposed to be annexed to the District. The ROI provides that the special taxes heretofore caused to be levied in the District shall be levied in the territory proposed to be annexed, subject to public hearing and owner consent proceedings as specified in the Act.
At the public hearing the testimony of all interested persons for and against the annexation of said territory to the District or the levying of special taxes within the territory proposed to be annexed will be heard. Any person interested may file a protest in writing with the City Clerk.
Isl Brenda Pree
City Clerk
City of Palm Springs
Item 1F - Page 23
CITY COUNCIL STAFF REPORT
DATE: MARCH 27, 2025 CONSENT CALENDAR
SUBJECT: APPROVE A RESOLUTION OF INTENTION AND PROPOSED
BOUNDARY MAPS TO ANNEX TERRITORY TO COMMUNITY
FACILITIES DISTRICT NO. 2005 -1 (PUBLIC SAFETY SERVICES) , ANNEXATION NO. 27, SIENA, TRACT MAP NO. 38846
FROM: Scott C. Stiles, City Manager
BY: Engineering Services Department
SUMMARY:
The
City Coun cil previously estab lished Comm unity Fa cilities Dis trict 2005-1 (Pub lic Safety Services, CFD 20 05-1) in October 20 05 to levy a s pecial tax on properties identified as “fee statu s” (non-Indian A llottee Leased or n on-Tribal Trust p roperties) located within the City, to provide a financing mechanism to sustain the delivery of public safety services to new residential developments located on those properties. This action declares the City Council’s intention to annex additional property identified as Annexation No. 27 for Tract Map No. 38846; the action also schedules a Public Hearing for May 14, 2025, to officially annex the additional property into CFD 2005-1.
RECOMMENDATION:
1) Adopt Resolution No. _____, “A RESOLUTION OF THE CITY COUNCIL OF THE
CITY OF PALM SPRINGS, CALIFORNIA, DECLARING ITS INTENTION TO
ANNEX TERRITORY INTO A COMMUNITY FACILITIES DISTRICT TO
AUTHORIZE THE LEVY OF SPECIAL TAXES FOR THE CITY OF PALM SPRINGS COMMUNITY FACILITIES DISTRICT NO. 2005 -1, (PUBLIC SAFETY SERVICES), ANNEXATION NO. 27, SIENA, TRACT MAP NO. 38846.”
2) Set the public hearing for 5:30 p.m. on May 14, 2025, for public comment and for the filing of written protest by any property owner regarding the annexation of territory to CFD 2005-1, the levy of a special tax for public safety services, and a special landowner election.
Item 1G - Page 1
City Council Staff Report
March 27, 2025 -- Page 2
CFD No. 2005-1 (Annexation No. 27 – Siena)
STAFF ANALYSIS:
The Ci ty Council created Community Facilities District 2005-1 (Public Safety Services) (CFD 2005-1) to allow the City to levy a special tax on certain properties identified as “fee status” (non-Indian Allottee Leased or T ribal Trust properties) located within the City to provide a fi nancing mechanism to susta in the de livery of public safety services to n ew residential developments located on t hose properties. This type of financing pr ogram, which is authorized under the Mello-Roos Community Fac ilities A ct of 1982, envisioned the participation of all future new residential development projects on “fee status” lands, either by formation of new districts or as an annexation into CFD 2005-1.
As
new residential developments on fee status l ands have been approved by the City, they are conditionally approved with a requirement to annex into CFD 2005-1. CFD 2005- 1 was specifica lly es tablished separately from the City’s ot her district, Comm unity Facilities District 2007-1 (Public Safety Services, CFD 2007-1), for developments located on Indian Allottee Leased or Tribal Trust lands that cannot be annexed into the existing CFD 2005-1 due to their unique ownership status.
At this time, one residential de
velopment approved on fee status land is recommended
for annexation into CFD 2005-1:
Annexation No. 27 – Tract Map No. 38846, a residential development consisting of 60 multi-family condominiums, located on North Palm Canyon Dr, north of West Vista Chino.
In orde
r to com mence the annexation process, the City Council is r equired to a dopt a Resolution of Intention (ROI). The Resolution sets forth terms and conditions for annexing property i nto CFD 2005-1 and inclu des the ra te and method o f apportionment of the special tax to be levied. The Resolution also schedules a Public Hearing on the proposed annexation, which by statute must be held between 30 to 60 days following the adoption of the Resolution. In accordance with this requirement, staff recommends tha t the Public Hearing be scheduled for May 14, 2025. Pursuant to the Mello-Roos Community Facilities Act of 1982, there are less than 12 r egistered voters on the property to be annexed into CFD 2005-1; therefore, the special election will be a landowner vo te within t he annexation.
P
roperty owners within the territory to be annexed into the District have executed and submitted a petition with waivers to the City, waiving certain timing and noticing requirements under the Election Code. This will enable the City to expedite the annexation process by holding the special election immediately after the public hearing on May 14, 2025.
The special tax currently being assessed on properties within CFD 2005-1 is based upon a Fiscal Impact Analysis that was prepared by MuniFinancial. Based on this analysis, the Fiscal Year 2 024/25 special tax for a multi- family residence is $ 486.58 per year. Other Item 1G - Page 2
City Council Staff Report
March 27, 2025 -- Page 3
CFD No. 2005-1 (Annexation No. 27 – Siena)
rates are detailed in the Rate and Method of Apportionment, included as Exhibit D of the referenced resolution. The special tax is collected as part of the Riverside County annual property tax bill.
ENVIRONMENTAL ASSESSMENT:
The req ue
sted City C ouncil act ion is no t a “Project” as defined by the Ca lifornia Environmental Quality Act (CEQA). Pursuant to Section 15378(a), a “Project” means the whole of an action, which has a potential for resulting in either a direct physical change in the environment, or a r easonably fores eeable i ndirect physical change in t he environment. The requested action is to authorize annexation of certain properties into CFD 2005-1, and is exempt from CEQA pursuant to Section 15378(b), in that a “Projec t” does not include: (5) Or ganizational or administrative activities of governments that will not result in direct or indirect physical changes in the environment.
FISCAL IMPACT:
CFD 2005-1 funds are exclusively allocated for public safety services. In fiscal year 2024- 25, CFD 2005- 1 included 2,851 taxable parcels, generating a total levy of $1,267,101.
Upon annexation of the Siena development into CFD 2005-1 and the issuance of building permits for the new units, the special tax will generate an additional $29,194 annually based on the proposed 60 multi -family units, based on Fiscal Year 2024- 25 multi-family home special tax rates.
REVIEWED BY:
City Engineer Joel Montalvo
Deputy City Manager: Flinn Fagg
City Manager: Scott Stiles
ATTACHMENTS:
A. Resolution
Item 1G - Page 3
ATTACHMENT A
Item 1G - Page 4
RESOLUTION NO.
A RESOLUTION OF THE CITY COUNCIL OF THE CITY OF
PALM SPRINGS, CALIFORNIA, DECLARING ITS
INTENTION
TO ANNEX TERRITORY INTO A COMMUNITY
FACILITIES DISTRICT TO AUTHORIZE THE LEVY
OF SPECIAL TAXES FOR THE CITY OF PALM
SPRINGS COMMUNITY FACILITIES DISTRICT
NO.
2005-1 (PUBLIC SAFETY SERVICES)
ANNEXATION NO. 27 SIENA, TRACT # 38846
WHEREAS, under the Mello-Roos Community Facilities Act of 1982 (Sections 53311 and following, California Government Code; hereafter referred to as the "Act"), the City Council of the City of Palm Springs (the "City") previously conducted proceedings to establish the City of Palm Springs Community Facilities District No. 2005-1 (Public Safety Services) (the "District"), and
WHEREAS
, under the Act, this City Council is the legislative body for the proposed annexation of territory to the District and is empowered with the authority to annex territory to the District
and levy special taxes within the annexation territory; and
WHEREAS
, the City Council has received petitions from all landowners (100%) within the proposed annexation territory, r equesting the City to initiate annexation proceedings into the District; and
WHEREAS
, this City Council now desires to commence proceedings to consider
the annexation of territory to the District.
THE CITY COUNCIL OF THE CITY OF PALM SPRINGS, CALIFORNIA, HEREBY RESOLVES, DETERMINES AND APPROVES AS FOLLOWS:
SECTION 1. This City Council proposes to begin the proceedings necessary to annex territory to the Distr
ict pursuant to the Act.
SECTION 2. The name of the existing District is City of Palm Springs, Community Facilities District No. 2005-1 (Public Safety Services).
SECTION 3.
A general description of the te rritory included in the existing District is shown on the boundary map recorded in t he office of the County Recorder for the County of Riverside on Novem ber 1, 2005, in Book 64, pages 71-77 of Maps of Assessments and Community
Facilities Districts, to which map reference is hereby made.
SECTION 4. The territory now proposed to be annexed to the District is shown on Annexation Map No. 27 of the District on f ile with the City Clerk, a copy of which is attached hereto as Exhib
it A, which Exhibit is, by this reference, inco rporated herein. The boundaries of which territory are hereby preliminarily approved and to which map Item 1G - Page 5
reference is hereby made for further particulars. The City Clerk is hereby directed to record, or cause to be recorded, said Annexat ion Map No. 27 of the District in the office of the County Recorder of t he County of Riverside within fifteen days of the date of adoption of this Resolution. The Tract Map(s) for the territory proposed to be annexed is attached as Exhibit B. The list of partici pating assessor’s parcels to be annexed is attached as Exhibit C.
SECTION 5. The types of services to be funded by the District and pursuant to the Act consist of those services (the "Services") described in Resolution No. 21402 entitled "A Resolution of the City Counc il of the City of Palm Springs , California, Declaring its Intention to Establish Community Facilities District No. 2005-1 (Public Safety Services) to Authorize the Levy of Specia l Tax Therein to Finance Cert ain Services" adopted by the City Council on September 7, 2005 (the "ROI" ), which ROI is, by this reference, incorporated herein. It is pres ently intended that the Services will relate to the existing territory in the District and the territory proposed to be annexed to the District.
SECTION 6. Except to the extent that funds are otherwise available to the District to pay for the Services, a special tax suffici ent to pay the costs thereof, secured by recordation of a continuing lien against all non-exempt real proper ty in the District (including the property being annexed thereto) , will be levied annually within the District and collected in the same manner as ordinary ad valorem property taxes, or in such other manner as this City Council shall determine, including direct billing of the affected property owners. The rate and method of apportionment of the special tax among the parcels of real property within the District, as now in existence and following the annexation proposed herein, in sufficient detail to allow each landowner within the territory proposed to be annexed to the District to estimate th e maximum amount such owner will have to pay, is attached in Exhibit D.
SECTION 7. The special tax proposed to be levied for Services to be supplied within the proposed territory to be annexed will be equal to the special taxes levied to pay for the same Services in the District, except that a higher or lower special tax may be levied within the proposed territory to be annexed to the extent that the actual cost of providing the Services in that territory is higher or lower t han the cost of providing those Services in the District. Notwithstanding the foregoing, the special tax may not be levied at a rate which is higher then the maximum special tax aut horized to be levied pursuant to the rate and method of apportionment of the special tax.
SECTION 8. Notice is given that on Wednesday, May 14, 2025, at 5:30 p.m. or as soon thereafter as the matter may be heard, in the regular meeting place of this City Council in the Council Chambers, at 3200 East Tahquitz Canyon Way, Palm Springs, California, 92262, and the same are hereby appointed and fixed as the time and place when and where this City Council, as legislative body for the District, will conduct a public hearing on the annexation of te rritory to the District and c onsider and finally determine whether the public interest, convenience, and necessity require said annexation of territory to the District and the levy of said special tax therein.
Item 1G - Page 6
SECTION 9. The City Clerk is hereby di rected to cause notice of said public hearing to be given by publication one time in a newspaper published in the area of the District. The publication of said notice shall be completed at least seven days before the date herein set for said hearing. The notice shall be substantially in the form of Exhibit E hereto.
SECTION 10. This Resolution shall take effect upon its adoption.
ADOPTED this 27th day of March 2025.
Scott Stiles, City Manager
ATTEST:
Brenda Pree, City Clerk
CERTIFICATION
STATE OF CALIFORNIA )
COUNTY OF RIVERSIDE ) ss.
CITY OF PALM SPRINGS)
I, BRENDA PREE, City Clerk of the City of Pa lm Springs, hereby certify that Resolution No. is a full, true, and correct copy, and was duly adopted at a regular meeting of the City Council of the City of Palm Springs on March 27, 2025, by the following vote:
AYES:
NOES:
ABSENT:
ABSTAIN:
Brenda Pree, City Clerk
City of Palm Springs, California
Item 1G - Page 7
EXHIBIT A
PROPOSED BOUNDARIES OF THE ANNEXATION TERRITORY
CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2005-1
(PUBLIC SAFETY SERVICES)
ANNEXATION NO. 27
SIENA, TRACT # 38846
Item 1G - Page 8
Item 1G - Page 9
,_ ___________ ~ _______ W_Vista Chino
C J,
...
0 I
C:
0 >,
C:
(tJ
u
I
C:
(tJ
"C
C:
z
CLERK 'S MAP FILING STATEMENT
FILED IN THE OFFICE OF THE CITY CLERK OF THE
CITY OF PALM SPRINGS THIS DAY OF 2025.
CLERK OF THE BOARD
CLERK 'S MAP CERT IFICATE
I DO H EREBY CERT IFY THAT THE WITH IN MAP SHOWING
TERRITORY PROPOSED TO BE ANNEXED INTO
COMM UNITY FACILITIE S DISTRICT NO. 2005- 1
(PUBLIC SAFETY SERVICES ),
CITY OF PALM SPRINGS , COUNTY OF RIVERSIDE ,
STATE OF CALIFORN IA,
WAS APPROV ED BY THE CITY COUNCIL OF THE
CITY OF PALM SPRINGS
AT A MEET ING THEREOF, HELD ON
THE DAY OF _____ , 2025,
BY ITS RESOLUTION NO. ___ _
CLERK OF THE BOARD
RECORDER'S CERTIFICATE
FILED THIS DAY OF~--~ • 2025 AT THE
HOUR OF ~~~~ O'CLOCK IN BOOK
OF MAPS OF ASSESSMENT AND COMMUN ITY FA- C~I_LI_T-IE~S
DISTRICTS AT PAGE ___ IN THE OFFICE OF THE COUNTY
RECORDER IN THE COUNTY OF RIVERSIDE ,
STATE OF CALIFO RNIA
COUNTY RECORDER , COUNTY OF RIVERS IDE
NOTE:
REFERENCE IS HEREBY MADE TO THAT CERTAIN MAP
ENTITLED "CITY OF PALM SPRINGS COMMUN ITY FACILITIES
DISTRICT NO. 2005-1 (PUBLIC SAFETY SE RVICES)," RECORDED
WITH THE RIVERSIDE COUNTY RECORDER 'S O FFICE ON
NOVEMB ER 1, 2005 AS DOC UMENT NO. 2005-0804134, IN BOOK 64, PAGES 71-77, OF MAPS OF ASSESSMENT AND COMMUN ITY
FACILITIES DISTR ICTS.
REFERE NCE IS HEREBY MADE TO THE MAPS AND DEEDS OF
RECORD IN THE OFFICE OF THE ASS ESSOR OF THE COU NTY
OF RIVERS IDE FOR A DETAILED DESCRIPTION OF THE LINES
"C ~ ,._ AND DIMENSIONS OF ANY PARCELS SHOWN HERE IN. THOSE 0:: O MAPS SHALL GOVERN FOR ALL DETAILS CONCERNING THE
L ~J
~ ctJ c: I LINES AND DIMENSIONS OF SUCH PARCELS. EACH PARC EL IS ~ w Via Sol ~ g_ I IDENTIFIED IN SAID MAPS BY ITS DISTINCT IVE ASS ESSOR'S w Via Sol C: PARCELNUMBER(APN ).
I--'-'--'-'-"'---------------------------'"-'----------------'------'----' Legend
Proposed Boundaries of CFD No. 2005-01 Annexation No. 27 D City of Palm Springs Parcels
SCIConsultingGroup
Pu b lic Fi na nce Co n sul t i n g Ser v ices
Assessor's Parcel Numbe rs:
504-310-027
ANNEXATION MAP NO. 27 OF
COMMUNITY FACILITIES DISTRICT NO. 2005-1
(PUBLIC SAFETY SERVICES) OF THE COUNTY OF
RIVERSIDE , STATE OF CALIFORNIA
EXHIBIT B
TRACT MAP OF THE PROPOSED ANNEXATION TERRITORY
CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2005-1
(PUBLIC SAFETY SERVICES)
ANNEXATION NO. 27 SIENA, TRACT # 38846
Item 1G - Page 10
Item 1G - Page 11
0 • ~
-----
_ _/
/
IN THE CITY OF PALM SPRINGS, COUNTY OF RIVERSIDE , STATE OF CALI FORNIA TENTATIVE PARCEL MAP 38846
BEING A SUBDIVISION OF PARCEL 1, PA RCEL MAP NO. 12937, P.M.B. 94151-53, RECORDS OF RIVERSIDE COUNTY, LOCATED IN THE SE 114 OF THE SE 1/4 OF SECTION 3,
~
$ftl."'5 ' R I
/
PAR~CEL 1
..4.-;J/ ACRtS
J BJ,84 9.8 9 1 S (.),
/
r ! .
TOWNSHIP 4 SOUTH, RANGE 4 EAST, S.B.M .
'FOR CONDOMINIUM PURPOSES'
;;;f,
'·
---~---·----
/
/
' "
/
/
/
/
~ --- -=----- ----- --- -
/ .,
'> ;
/
' '-
(
\
/ I
I I
\
\
--✓
I
)
\
... ~
/~ ~
/ \
\ ~ :
~ \
- - _I
/-----'-----------f
' -
~3~3--·-,- 'J ~ ·· . I \
}
l \
___JIJ§_TAyHmQ__ _ , _ __ ''.,__ _ _ _
'ro COPffi1'•1EU),
80/T O',U (SHOT AT
BQ,O) OQWIII 0.!1'
A HEITEC
1 ... .. .. , .. ,., ... .
SuiM30 9
n1ust r....., c.n,...W..y
C O N S U L T I N [3 Palm ~.::~~~!;;;'.:!22U
SCALE
"
VICINITY MAP
NOT TO SCA.LC
LEGAL DESCRIPTION
1H£ t..AHD ~CO TO HE:Rf/N BE"LOW IS StnMTE"O IN THE: CITY OF P.AUI SPRINGS, COUNTY OF Rl\lERSIDE, STATE OF CAI.FORNIA, NJ() IS DESCRIBfD AS FOU.OWS,
PARCEL 1 OF PAR(;(L i,up HQ_ 1211J7, !H 1H£ CITY OF PAUi SPR1HG'S, COUNTY OF RIVE'RSIOE", STATE OF CALJF'ORHI,\ AS SHOWN BY MAP OH Fll.C tN 800I( 94, PN;ES 5 1 TO 5J, INCLVSM OF PN<CU AW'S, RE:OORDS OF RNERStD£ COUNTY, c.,,,,,.,.._ APH..· 50f-J I0-027 - 6
BASIS OF BEARINGS
SURVEYOR'S NOTES
(RI) iNDfCAr£S R£CORD !MTA P£R P.11. 12!:IJl, BOOK 94
PAGES !ll- .5J
THIS TENT.UM PN?Cfl MAP C01'JTAJNS:
1'0TAI. CROSS AA£/t • 4.22 ACRES (1 5J.8"'9.e9r sa. FT.) EASEMENr NOTES
Dl. CX!S71NG
S.F. 50!.Wl[" rEU
R/'N RJOHr OF WAY
c,;,m,,u,;;;
TRACT OOUNDt.RY
RIGHT OF WAY
0 ~~-IN~~~~: JJ.:cf~~ coC::,,:::, /
COflPORATION rot( THC PURPOSE: or PC/..I LJNCS. kCC0'10£D WJ?Cfl .31. , ~, fN BOOK 2879, PAC£ 5~. O.R.
0 ~~~ o:'~J.B~~INAS~"::.~~S)~,,,.S~ 5J.
0 ~;r~~ro:::n~:r::: t:::r RC~~SHO~n9M/.O
0'1.
0 ~::;,::T(zJ-~~~~~1.si~t::: · ~~rio~ ~'[::
R£CORO£:O >F'f?IL 2, IP-" , RCCOROING NO; &1074, O.R
0 ~r~ ~Jt'~ gr~~Hu~~t~~r=~ Y
Sl'$10,IS, CQl&uMC,,TfON SYSTCMS. RECOROCD MARCH 13. 1.9.96. RC:.CORDINC NO: 05S.552, O.R.
I.JTUTY PURVEYORS
OCSDrrWA'IERAG£NCY
1200 S. GEN£ AUTRY TRArL
PJLJJ SPRJNGS. CA 92262
(760) .J2J-'497I
SO. CALJFORNIA EDISON
36100 CA1l-1£DR.111. CNh'ON DR.
CArn£M4L CITY. CA i22J4
(760 ) 202- -4291
SPECTRUM
.f I 72-' CO()f( STR(( T
PN.J,I OCSERf, C4 9221T
(760 ) 6 74- 5472
OWNER
£V£'RGRITN AINNJTNJE, UC
1-t2• "TI-I sma:r. srr 1n
~~'~:;:,gowi
DEVELOPER
MARK WORTIAANN
.x,, SAA <NWMO
~ DIEGO, CA 92106
fll_: J2J.f505.JJ l 7
'""'"1ER
295 N, SUNRtSt: WAY
PALU SPRJNGS. CA 92262
(IJOO) 48.3- •CIOO
SO. OOtfORNIA. ~ COMPN('(
2'1 N. SUNRJS£ WAY
PAUi $/'RJN<:$, CA i2262
(BOO) 427- 2200
ClrY OF PJ,LJ,I SPRINCS
C/0 w£0CIA WATCR ( SfM"R)
P.O. BOX 270J
J200 T~ CANYON WAY
PAUi Sl'RJNCS. CA 92262
( 760) JZJ- 8 16$ D<T. 2
PREPARED BY
HEIT£C CONSULTING
~£~ TAHQUfTZ ~ WM
PAJ.M SPRrNGS, CA 92262
m, 1ro.J<10.9060
aTY OFPALJIBPfWJSS
1EWTA TIVE PARCEL MAP 38846
APH 504-3fHl27 1
OF 1 SI-T:S
EXHIBIT C
LIST OF PARTICIPATING ASSESSOR’S PARCELS
CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2005-1
(PUBLIC SAFETY SERVICES)
ANNEXATION NO. 27 SIENA, TRACT # 38846
APN ACRES LANDOWNER
504‐310‐027 4.37 PALM CANYON MONAGHAN
Item 1G - Page 12
EXHIBIT D
RATE AND METHOD OF APPORTIONMENT
CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2005-1
(PUBLIC SAFETY SERVICES)
A Special Tax of Community Facilities District No. 2005-1 (Public Safety Services) of the City of Palm Springs (the “District”) shall be levied on all Assessor’s Parcels in the District and collected each Fiscal Year commencing in Fiscal Year 2006-07 in an amount determined by the City through the application of the rate and method of apportionment of the Special Tax set forth below. All of the real property in the District, unless exempted by law or by the provisions hereof, shall be taxed for the purposes, to the extent and in the manner herein provided.
A. DEFINITIONS
The terms hereinafter set forth have the following meanings:
“Acre of Acreage” means the land area of an Assesso r’s Parcel as shown on an Assessor’s Parcel Map, or if the land area is not shown on an Assessor’s Parcel Map, the land area shown on the applicable final subdivi sion map, other final map, other parcel map, other condominium plan, or functionally equivalent map or inst rument recorded in the Office of the County Recorder. The squar e footage of an Assessor’s Parcel is equal to the Acreage multiplied by 43,560.
“Act” means the Mello-Roos Community Facilities Act of 1982, being Chapter 2.5, Part 1, Division 2 of Title 5 of t he Government Code of the State of California, as amended, which authorizes the establishment of the District to finance: a) police protection services, and b) fire protection and suppression services, and life safety services including but not limited to ambulance and paramedic services.
“Administrative Expenses” means the actual or estimated costs incurred by the City as administrator of the District to determine, levy and collect the Special Taxes, including the proportionate amount of the sa laries and benefits of City employees whose duties are directly related to administration of the District and the fees of consultants, legal counsel, the costs of collecting inst allments of the Special Ta xes upon the general tax rolls, preparation of required reports; and any other costs required to administer the District as determined by the City.
“Annual Escalation Factor” means the greater of the increase in the annual percentage change of the All Urban Consumers Consumer Price Index (CPI) or the percent increase of salaries and benefits for public safety employees as stated in the Memorandum of Understanding for the fiscal year of the Special Tax. The annual CPI used shall be for the area of Los Angeles-Riverside- Orange County, CA as reflected in the then-current April Item 1G - Page 13
update. The annual CPI used shall be as determined by the United States Department of Labor, Bureau of Labor Statistics, and may be obtained through the California Division of Labor Statistics and Research (www.dir.ca. gov/dlsr). If the fo regoing index is not available, the District Administrator shall select a reasonably comparable index.
“Assessor’s Parcel” means a lot or parcel shown in an Assessor’s Parcel Map with an assigned assessor’s parcel number.
“Assessor’s Parcel Map” means an official map of the Assessor of the County designating parcels by assessor’s parcel number.
“Base Year” means Fiscal Year ending June 30, 2007.
“BIA” means the Bureau of Indian A ffairs within the Department of the Interior and any tribe acting on behalf of the BIA.
“City” means the City of Palm Springs.
“Council” means the City Council of t he City of Palm Springs, acting as the legislative body of the District.
“County” means the County of Riverside, California.
“Developed Multi-Family Residence” means an Assessor’s Parcel of Developed Property for which a building permit has been issued for purposes of constructing a residential structure consisting of more t han one residential Dwelling Unit which share common walls, including, but not limited to, duplexes, triplexes, town homes, condominiums, and apartment units.
“Developed Property” means all Taxable Property, e xclusive of Property Owner Association Property, Non-Residential Property, or Public Property, for which a building permit was issued after January 1, 2006, and prior to May 1 st preceding the Fiscal Year in which the Special Tax is being levied.
“Developed Single-Family Residence” means an Assessor’s Parcel of Developed Property for which a building permit(s) has been issued for purposes of constructing one single-family residential Dwelling Unit.
“District Administrator” means an official of the City, or designee thereof, responsible for determining the Special Tax Requirement and providing for the levy and collection of the Special Taxes.
“District” means Community Facilities District No. 2005-1 (Public Safety Services) of the City of Palm Springs.
Item 1G - Page 14
“Dwelling Unit” means any separate residential unit in which a person or persons may live, which includes provisions for sleeping, cooking and sanitation, and is not considered to be for commercial or industrial use.
“Entitled Property” means an Assessor’s Parcel and/or Lot in the District, which has a Final Map recorded prior to January 1 st preceding the Fiscal Year in which the Special Tax is being levied, but for which no building permit has been issued prior to the May 1st preceding the Fiscal Year in which the Special Tax is bei ng levied. The term “Entitled Property” shall apply only to Assessors’ Parcels and/or Lots, which have been subdivided for the purpose of residential development, e xcluding any Assessor’s Parcel that is designated as a remainder parcel determined by final documents and/or maps available to the District Administrator.
“Final Map” means an Assessor’s Parcel Map, a final subdivision map, other parcel map, other final map, other condomin ium plan, or functionally equi valent map that has been recorded in the Office of the County Recorder.
“Fiscal Year” means the period starting July 1 and ending on the following June 30. “Land Use Class” means any of the classes listed in Table 1. “Lot” means property within a recorded Final Map identified by a lot number for which a building permit has been issued or may be issued.
“Maximum Special Tax” means the maximum Special Ta x, determined in accordance with Section C below that can be levied in the District in any Fiscal Year on any Assessor’s Parcel.
“Non-Residential Property” means all Assessors’ Parcels for which a building permit(s) has been issued for a non-residential used and does not contain any residential units as defined under Developed Single Family Residence or Developed Multi-Family Residence. “Property Owner Association Property” means any property within the boundaries of the District that is owned by, or irrevocabl y dedicated as indicated in an instrument recorded with the County Recorder to a property owner association, including any master or sub-association.
“Proportionately” means in a manner such that the ration of the actual Special Tax levy to the Maximum Special Tax is equal for all Assessor’s Parcels within each Land Use Class.
“Public Property” means any property within the boundaries of the District that is, at the time of the District formation or at the time of an annexation, expected to be used for rights- of-way, parks, schools or any other public purpose and is owned by or irrevocably offered for dedication to the federal government, the State, the County, t he City or any other public agency.
Item 1G - Page 15
“Public Safety Service Costs” means the estimated and reasonable costs of providing police services and fire protection and suppre ssion services and life safety services, including but not limited to (i) the costs of contracting servic es, (ii) equipment, vehicles, ambulances, and paramedics, fire apparatus, supplies, (iii) the salaries and benefits of City staff that directly provide police services and fire protection and suppression services and life safety services, respectively, and (iv) City overhead costs associated with providing such services within the District. On each Ju ly 1 following the Base Year the increases attributed to salaries and benefits shall be calculated and limited to the increase based on the Annual Escalation Factor. The Special Tax provides only partial funding for police, fire and life safety services.
“Special Tax” means the Special Tax to be levied in each Fiscal Year on each Assessor’s Parcel of Taxable Property to fund the Special Tax Requirement, and shall include Special Taxes levied or to be levied under Sections C and D, below.
“Special Tax Requirement” means that amount required in any Fiscal Year for the District to: (i) pay for Public Safety Servic e Costs; (ii) pay reas onable Administrative Expenses; (iii) pay any amounts required to establish or replenish any reserve funds; and (iv) pay for reasonably anticipated delinquent Special Taxes based on the delinquency rate for Special Taxes levied in the previ ous Fiscal Year; less any surplus of funds available from the previous Fiscal Year’s Special Tax levy. “State” means the State of California.
“Taxable Property” means all of the Assessor’s Parc els within the boundaries of the District and any future annexation to the District that are not exempt from the Special Tax pursuant to law or as defined herein.
“Tax-Exempt Property” means an Assessor’s Parcel not subject to the Special Tax.
Tax- Exempt Property includes: (i) Public Property, (ii) Property Owner Association Property, (iii) Non- Residential Property, and (iv) property designated by the City or District Administrator as Tax- Exempt Property.
“Undeveloped Property” means, for each Fiscal year, all Assessor’s Parcels of Taxable Property not classified as Developed Property or Entitled Property, including an Assessor’s Parcel that is designated as a remainder parcel and is not identified as potential Public Property by any final documents and/or maps available to the District Administrator.
“Unit” means any separate residential dwelling unit in which a person or persons may live, which comprises an independent facility capabl e of conveyance separate from adjacent residential dwelling units and is not considered to be for commercial or industrial use.
B. ASSIGNMENT TO LAND USE CATEGORIES
Each Fiscal Year using the definitions abov e, all property within the District shall be classified as either Developed Property or Tax-Exempt Property. Developed Property shall be further classified as Developed Single-Family Residence or Developed Multi- Item 1G - Page 16
Family Residence. Commenci ng with the Base Year and for each subsequent Fiscal Year, all Developed Property shall be subject to Special Taxes pursuant to Sections C and D below.
C. MAXIMUM SPECIAL TAX RATE
1. Developed Property
TABLE 1
Maximum Special Tax for Developed Property
Community Facilities District No. 2005-1
(Public Safety Services)
Land
Use
Class
Description Maximum
Special Tax
1 Developed Single-Family Residence
$350 per Dwelling
Unit
2 Developed Multi-Family Residence
$295 per Dwelling
Unit
On each July 1 following the Base Year (i.e., July 1, 2007), the Maximum Special Tax Rates in Table 1 shall be increased in accordance with the Annual Escalation Factor. Once the Maximum Special Tax per Dwelling Unit is equal to $500 per Dwelling Unit, no further Annual Escalation Factor shall be applied and the Maximum Special Tax per Dwelling Unit shall not exceed $500.
2. Entitled Property
Table 2
Maximum Special Tax for Entitled Property
Community Facilities District No. 2005-1
(Public Safety Services)
Land Use Class
Description
Maximum Special Tax
Per Lot
3 Entitled Property $100 per Lot
No Annual Escalation Factor shall be applied to the Maximum Special Tax per Lot for Entitled Property.
Item 1G - Page 17
3. Undeveloped Property
Undeveloped Property will be assigned a Maximum Special Tax Rate of $500 per Acre or portion thereof, with a mi nimum rate of $100 for Undeveloped Property less than or equal to one-fourth (1/4) of an Acre as described in Table 3.
Table 3
Maximum Special Tax for Undeveloped Property
Community Facilities District No. 2005-1
(Public Safety Services)
Land Use Class
Description Maximum Special Tax
Per Parcel/Acre
4 Undeveloped Property less
than or equal to ¼ Acre
$100 per
Assessor’s Parcel
5 Undeveloped Property > ¼
Acre
$500 per Acre
No Annual Escalation Factor shall be applied to the Maximum Special Tax per Parcel/Acre for Undeveloped Property.
4. Tax-Exempt Property
No Special Tax shall be levied on Tax-Exempt Property.
5. Multiple Land Use Classes
In some instances an Assessor’s Parcel may contain more than one Land Use Class. The Maximum Special Tax levied on an Assessor’s Parcel shall be the sum of the Maximum Special Tax levies that can be imposed on all Land Use Classes located on that Assessor’s Parcel.
D. METHOD OF APPORTIONME NT OF THE SPECIAL TAX
Commencing with Fiscal Year 2006-07, and for each subsequent Fiscal Year, the District Administrator shall calculate the Special Ta x Requirement based on the definitions in Section A and levy the Special Tax as follows until the amount of the Special Tax levied equals the Special Tax Requirem ent. First, the Special Tax shall be levied each Fiscal Year on each Assessor’s Parcel of Developed Property Proportionately between Developed Single-Family Residence and Developed Multi-Family Residence up to 100% of the applicable Maximum Special Tax. Second, if the Special Tax Requirement has not been satisfied by the first step, then the Special Tax shall be levied each Fiscal Year on Item 1G - Page 18
each Assessor’s Parcel of Entitled Property up to 100% of t he applicable Maximum Special Tax for Entitled Property. Lastly, if the first two steps have not satisfied the Special Tax Requirement, then the Special Tax s hall be levied each Fiscal Year on each Assessor’s Parcel of Undeveloped Property up to 100% of the applicable Maximum Special Tax for Undeveloped Property.
E. APPEALS
Any tax payer that believes that the amount of the Special Tax assigned to an Assessor’s Parcel is in error may file a written notice with the District Administrator appealing the levy of the Special Tax. This notice is required to be filed with the District Administrator during the Fiscal Year the error is believed to ha ve occurred. The District Administrator or designee will then promptly review the appeal and, if necessary, meet with the taxpayer.
If the District Administrator verifies that the tax should be changed the Special Tax Levy shall be corrected and, if applicable in any case, a refund shall be granted.
F. EXEMPTIONS
1. Residential Property
Residential Properties which annually meet one or more of the following standards shall be exempt from payment of the Special Tax:
a. A Residential Property consisting of one or two person(s) earning $15,300 or less gross income per year, upon complying with procedures to establish such exemption, or
b. A Residential Property consisting of three persons earning $17,900 or less gross income per year, upon complying with procedures to establish such exemption, or
c. A Residential Property which qualifies for either the Low Income Rate Assistance (LIRA) exemption for electric al or gas services or the Lifeline exemption for telephone services.
The City is authorized and directed to promulgate administrative rules and procedures for verification of eligibility for the exemptions referred to in section F.
G. MANNER OF COLLECTION
Special Tax as levied pursuant to Section D above shall be collected in the same manner and at the same time as ordinary ad valorem property taxes; provided, however, that the District Administrator may directly bill the S pecial Tax, many collect Special Taxes at a different time or in a different manner if necessary to meet the financial obligations of the District or as otherwise determined appropriate by the District Administrator.
Item 1G - Page 19
H. TERM OF SPECIAL TAX
Every Five years after the establishment of the District, the City Council may reexamine, if deemed necessary by City Council, the necessity of the continuance of the Special Tax through the preparation of a Fi scal Impact Analysis, otherwis e the Special Tax shall be levied in perpetuity.
Item 1G - Page 20
EXHIBIT E
NOTICE OF PUBLIC HEARING
:Notice is hereby given that the City Council of t he City of Palm Springs will conduct a public hearing on Wednesday, May 14, 2025, at 5: 30 p.m. or as soon thereafter as the matter may be heard, in the City Council Chambers located at 3200 East Tahquitz Canyon Way, Palm Springs, California , 92262, to consider the following:
CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2005-1
(PUBLIC SAFETY SERVICES)
ANNEXATION NO. 27
SIENA, TRACT # 38846
On March 27, 2025, the City Co uncil, as the legislative body for the District, adopted a resolution entitled "A Resolution Of The City Council Of The City Of Palm Springs, California, Declaring Its Intention To Annex Te rritory Into A Community Facilities District To Authorize The Levy Of Special Taxes" (t he "ROI"). Pursuant to the ROI, the City Council determined that the public convenienc e and necessity require that certain territory, as more particularly described in the ROI, be annexed to the existing District, all as provided in the Mello-Roos Community Facilities Act of 1982 (Sections 53311 and following, California Government Code) (the "Act"). Reference is hereby made to the ROI, on file with the City Clerk of the City for further par ticulars. The following is a summary of the provisions of the ROI.
In the ROI, the City Council declared its intention to annex territory into Community Facilities District No. 2005-1 (Public Safety Services) (the "District"). The area proposed to be annexed to the District is as shown on Annexation Map No. 27, on file with the City Clerk, and identified in Exhibit A of the ROI. The District shall fund police services, fire protection and suppression services, and life safety services. It is presently intended that the services will be provided, without preference or priority, to the existing territory in the District and the territory proposed to be annex ed to the District. The ROI provides that the special taxes heretofore caused to be le vied in the District shall be levied in the territory proposed to be annexed, subject to public hearing and owner consent proceedings as specified in the Act.
At the public hearing the testimony of all interested persons for and against the annexation of said territory to the District or the levying of special taxes within the territory proposed to be annexed will be heard. Any person interested may file a protest in writing with the City Clerk.
Isl Brenda Pree
City Clerk
City of Palm Springs
Item 1G - Page 21
CITY COUNCIL STAFF REPORT
DATE: M ARCH 27, 2025 CONSENT CALENDAR
SUBJECT: APPROVE RESOLUTION OF INTENTION AND PROPOSED BOUNDARY
MAPS TO ANNEX TERRITORY TO COMMUNITY FACILITIES DISTRICT NO. 2005- 1 (PUBLIC SAFETY SERVICES) ANNEXATION NO. 28 , SERENA PARK, TRACT MAP NUMBERS 39025, 36691- 1, 36691- 2, 36691-3, 36691-4, 36691-5, 36691-6, AND 36691
FROM: Scott C. Stiles, City Manager
BY: Engineering Services Department
SUMMARY:
The
City Coun cil previously estab lished Comm unity Fa cilities Dis trict 2005-1 (Pub lic Safety Services, “CFD 20 05-1”) in October 20 05, to levy a s pecial tax on properti es identified as “fee statu s” (non-Indian A llottee Leased or n on-Tribal Trust p roperties) located within the City, to provide a financing mechanism to sustain the delivery of public safety services to new residential developments located on those properties. This action declares the City Council’s intention to annex additional property identified as Annexation No. 28 ( for Tract Map N umbers 39025, 36691-1, 36691-2,36691-3, 36691-4, 36691-5, 36691-6, and 36691); the action al so schedules a Public Hearing for Wednesday, May 14, 2025, to officially annex the additional property into CFD 2005-1.
RECOMMENDATION:
1) Adopt Resolution No. _____, “A RESOLUTION OF THE CITY COUNCIL OF THE
CITY OF PALM SPRINGS, CALIFORNIA, DECLARING ITS INTENTION TO
ANNEX TERRITORY INTO A COMMUNITY FACILITIES DISTRICT TO
AUTHORIZE THE LEVY OF SPECIAL TAXES FOR THE CITY OF PALM SPRINGS COMMUNITY FACILITIES DISTRICT NO. 2005-1, (PUBLIC SAFETY SERVICES), ANNEXATION NO. 2 8, TRACT MAP NUMBERS 39025, 36691- 1, 36691-2, 36691-3, 36691-4, 36691-5, 36691-6, AND 36691.”
2) Set the public hearing for 5:30 p.m. on May 14, 2025, for public comment and for the filing of written protest by any property owner regarding the annexation of territory to CFD 2005-1, the levy of a special tax for public safety services, and a special landowner election.
Item 1H - Page 1
City Council Staff Report
March 27, 2025 -- Page 2
CFD No. 2005-1 (Annexation No. 28 – Serena Park)
STAFF ANALYSIS:
The Ci ty Council created CFD 2005-1 to allow the City to levy a s pecial tax on certain properties identified as “fee status” (non-Indian Allottee Leased or Tribal Trust properties) located within the City to provide a financing mechanism to sustain the delivery of public safety services to new residential developments located on those properties. This type of financing program, which is authorized under the Mello-Roos Community Facilities A ct of 1982, envisioned the participation of all futur e ne w residential development projects on “fee status” lands, either by formation of new districts or as an annexation into CFD 2005-1.
As
new residential developments on fee status l ands have been approved by the City, they are conditionally approved with a requirement to annex into CFD 2005-1. CFD 2005- 1 was specifica lly es tablished separately from the City’s ot her district, Comm unity Facilities District 2007-1 (Public Safety Services, CFD 2007-1), for developments located on Indian Allottee Leased or Tribal Trust lands that cannot be annexed into the existing CFD 2005-1 due to their unique ownership status.
At this time, one residential de
velopment approved on fee status land is recommended
for annexation into CFD 2005-1:
Annexation No. 28 – Serena Park - Tract No. 39025, Tract No. 36691-1 (51 units), Tract No. 36691-2 (29 units), Tract No. 36691-3 (81 units) Tract No. 36691-4 (82 units), Tract No. 36691-5 (31 units), Tract No. 36691-6 (20 units) and Tract No. 36691 (92 units) Approximately 126 acres.
In orde
r to com mence the annexation process, the City Council is r equired to a dopt a Resolution of Intention (ROI). The Resolution sets forth terms and conditions for annexing property i nto CFD 2005-1 and inclu des the ra te and method o f apportionment of the special tax to be levied. The Resolution also schedules a Public Hearing on the proposed annexation, which by statute must be held between 30 to 60 days following the adoption of the Resolution. In accordance with this requirement, staff recommends that the Public Hearing be s c heduled for May 14, 2025. Pursuant to the Mello-Roos Community Facilities Act of 1982, there are less than 12 r egistered voters on the property to be annexed into CFD 2005-1; therefore, the special election will be a landowner vo te within t he annexation.
P
roperty owners within the territory to be annexed into the District have executed and submitted a petition with waivers to the City, waiving certain timing and noticing requirements under the Election Code. This will enable the City to expedite the annexation process by holding the special election immediately after the public hearing on May 14, 2025.
The special tax currently being assessed on properties within CFD 2005-1 is based upon a Fiscal Impact Analysis that was prepared by MuniFinancial. Based on this analysis, the Item 1H - Page 2
City Council Staff Report
March 27, 2025 -- Page 3
CFD No. 2005-1 (Annexation No. 28 – Serena Park)
Fiscal Year 2 024/25 s pecial tax for a multi- family resi dence is $486.58 per year and $500.00 for a single-family residence. Other rates are detailed in the Rate and Method of Apportionment, included as Exhibit D of the referenced resolution. T he special tax i s collected as part of the Riverside County annual property tax bill.
ENVIRONMENTAL ASSESSMENT:
The requested City Council action is not a “Project” as defined by the California Environmental Quality Act (CEQA). Pursuant to Section 15378(a), a “Project” means the whole of an action, which has a potential for resulting in either a direct physical change in the environment, or a reasonably foreseeable indirect physical change in the environment. The requested action is to authorize annexation of certain properties into CFD 2005-1, and is exempt from CEQA pursuant to Section 15378(b), in that a “Project” does not include: (5) Organizational or administrative activities of governments that will not result in direct or indirect physical changes in the environment.
FISCAL IMPACT:
CFD 2005- 1 funds are exclusively allocated for public safety services. In Fiscal Year 2024-25, 2,851 taxable parcels within the district were levied a total of $1,267,101 in special tax revenue. Upon annexation of Serena Park into CFD 2005-1 and the issuance of building permits for the new units, the special tax will generate an additional $193,000 annually based on the proposed 386 units, based on Fiscal Year 2024- 25 single-family home special tax rates.
REVIEWED BY:
City Engineer: Joel Montalvo
Deputy City Manager: Flinn Fagg
City Manager: Scott Stiles
ATTACHMENTS:
A. Resolution
Item 1H - Page 3
ATTACHMENT A
Item 1H - Page 4
RESOLUTION NO. _____
A RESOLUTION OF THE CITY COUNCIL OF THE CITY OF
PALM SPRINGS, CALIFORNIA, DECLARING ITS
INTENTION TO ANNEX TERRITORY INTO A COMMUNITY
FACILITIES DISTRICT TO AUTHORIZE THE LEVY OF
SPECIAL TAXES FOR THE CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2005-1 (PUBLIC
SAFETY SERVICES) ANNEXATION NO. 28 SERENA PARK,
TRACT #’s 39025, 36691-1, 36691- 2, 36691-3, 36691-4, 36691-5, 36691-6, 36691
WHEREAS, under the Mello-Roos Community Facilities Act of 1982 (Sections 53311 and following, California Government Code; hereafter referred to as the "Act"), the City Council of the City of Palm Springs (the "City") previously conducted proceedings to establish the City of Palm Springs Community Facilities District No. 2005-1 (Public Safety Services) (the "District"), and
WHEREAS, under the Act, this City Council is the legislative body for the proposed annexation of territory to the District and is empowered with the authority to annex territory to the District and levy special taxes within the annexation territory; a nd WHEREAS, the City Council has received petitions from all landowners (100%) within the proposed annexation territory, requesting the City to initiate annexation proceedings into the District; and
WHEREAS, this City Council now desires to commence proceedings to consider the annexation of territory to the District.
THE CITY COUNCIL OF THE CITY OF PALM SPRINGS, CALIFORNIA, HEREBY RESOLVES, DETERMINES AND APPROVES AS FOLLOWS:
SECTION 1. Thi s City Council proposes to begin the proceedings nece ssary to annex territory to the District pursuant to the Act.
SECTION 2. The name of the existing District is City of Palm Springs, Commun ity Facilities District No. 2005-1 (Public Safety Services).
SECTION 3. A general description of the territory included in the existing District is shown on the boundary map recorded in the office of the County Recorder for the County of Riverside on November 1, 2005, in Book 64, pages 71- 77 of Maps of Assessments and Community Facilities Districts, to which map reference is hereby made.
SECTION 4. The territory now proposed to be annexed to the District is shown on Annexation Map No. 28 of the District on file with the City Clerk, a copy of which is attached hereto as Exhibit A, which Exhibit is, by this reference, incorporated herein. The Item 1H - Page 5
boundaries of which territory are hereby preliminarily approved and to which map reference is hereby made for further particulars. The City Clerk is hereby directed to record, or cause to be recorded, said Annexation Map No. 28 of the District in the office of the County Recorder of the County of Riverside within fifteen days of the date of adoption of this Resolution. The Tract Map(s) for the territory proposed to be annexed is attached as Exhibit B. The list of participating assessor’s parcels to be annexed is attached as Exhibit C.
SECTION 5. The types of services to be funded by the District and pursuant to the Act consist of those services (the "Services") described in Resolution No. 21402 entitled "A Resolution of the City Council of the City of Palm Springs, California, Declaring its Intention to Establish Community Facilities District No. 2005-1 (Public Safety Services) to Authorize the Levy of Special Tax Therein to Finance Certain Services" adopted by the City Council on September 7, 200 5 (the " ROI"), which ROI is, by this reference, incorporated herein. It is presently intended that the Services will relate to the existing territory in the District and the territory proposed to be annexed to the District.
SECTION 6. Except to the extent that funds are otherwise available to the District to pay for the Services, a special tax sufficient to pay the costs thereof, secured by recordation of a continuing lien against all non -exempt real property in the District (including the property being annexed thereto), will be levied annually within the District and collected in the same manner as ordinary ad valorem property taxes, or in such other manner as this City Council shall determine, including direct billing of the affected property owners. The rate and method of apportionment of the special tax among the parcels of real property within the District, as now in existence and following the annexation proposed herein, in sufficient detail to allow each landowner within the territory proposed to be annexed to the District to estimate the maximum amount such owner will have to pay, is attached in Exhibit D.
SECTION 7. The special tax proposed to be levied for Services to be supplied within the proposed territory to be annexed will be equal to the special taxes levied to pay for the same Services in the District, except that a higher or lower special tax may be levied within the proposed territory to be annexed to the extent that the actual cost of providing the Services in that territory is higher or lower than the cost of providing those Services in the District. Notwithstanding the foregoing, the special tax may not be levied at a rate which is higher than the maximum special tax authorized to be levied pursuant to the rate and method of apportionment of the special tax.
SECTION 8. Notice is given that on Wednesday, May 14, 2025, at 5:30 p.m. or as soon thereafter as the matter may be heard, in the regular meeting place of this City Council in the Council Chambers, at 3200 East Tahquitz Canyon Way, Palm Springs, California, 92262, and the same are hereby appointed and fixed as the time and place when and where this City Council, as legislative body for the District, will conduct a public hearing on the annexation of territory to the District and consider and final ly determine whether the public interest, convenience, and necessity require said annexation of territory to the District and the levy of said special tax therein.
Item 1H - Page 6
SECTION 9. The City Clerk is hereby directed to cause notice of said public hearing to be given by publication one time in a newspaper published in the area of the District. The publication of said notice shall be completed at least seven days before the date herein set for said hearing. The notice shall be substantially in the form of Exhibit E hereto.
SECTION 10. This Resolution shall take effect upon its adoption.
ADOPTED this 27th day of March 2025.
Scott Stiles, City Manager
ATTEST:
Brenda Pree, City Clerk
CERTIFICATION
STATE OF CALIFORNIA )
COUNTY OF RIVERSIDE ) ss.
CITY OF PALM SPRINGS)
I, BRENDA PREE, City Clerk of the City of Palm Springs, hereby certify that Resolution No. ______ is a full, true, and correct copy, and was duly adopted at a regular meeting of the City Council of the City of Palm Springs on March 27, 2025, by the following vote:
AYES:
NOES:
ABSENT:
ABSTAIN:
Brenda Pree, City Clerk
City of Palm Springs, California
Item 1H - Page 7
EXHIBIT A
PROPOSED BOUNDARIES OF THE ANNEXATION TERRITORY
CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2005-1
(PUBLIC SAFETY SERVICES)
ANNEXATION NO. 28
SERENA PARK, TRACTS
39025, 36691-1, 36691-2, 36691-3,
36691-4, 36691-5, 36691-6, 36691
Item 1H - Page 8
Item 1H - Page 9
ltingGroup SCIConsu . Services
Consulting Pu b lic Finance
501-190-0 14
I Numbers : 's Paree
Assess~69-590-066
669-480-027
501-190-014
501-190-011
G STATEMENT
CLERK'S MAP FILIN HE CITY CLERK OF THE 2025.
OFFICE OFT DAY OF -FILED IN THE SPRINGS THIS CITY OF PALM
CLERK OF THE BOARD
CLERK'S MAP CERTIFICATE E WITHIN MAP SHOWING
RTIFY THAT TH NEXED INTO
I DO HER~~~~~POSED TOS~~I~~ NO. 2005- 1 TERRITO AGILITIES DI COMMUNITY F y SERVICES), OF RIVERSIDE, (PUBLIC SAE~TSPRINGS, COUNTY E CITY OF p~ALIFORNIA, TY COUNCIL OF TH STATE OF OVED BY THE Cl
WAS APPR PRINGS N
CITY OF PA~~ ~HEREOF, HELD O , 2025, AT A MEETI DAY OF
THE -ESOLU TION NO. BY ITS R
CLERK OF THE BOARD
RECORDER'S CERTIFICATE ' 2025 AT THE
DAY OF IN BOOK TIES FILED THIS - O 'CLOCK COMMUNITY FACl~IE HO~~~; OF ASSESSMENT ANI~ THE OF:~0Eo:siDE ,
grsTRICTS AT p:i:R IN THE COUNTY 0
COUNTY RECO FORNIA
STATE OF CALI OF RIVERSIDE
R COUNTY RECORDE ,
COUNTY MAP
THAT CERTAIN C ILITIES NOTE: HEREBY MADE TO S COMMUNITY F~ REFEREE~~~l~Y OF PALMB~~R~~~ETY SERV~~~]R DER'S ENTITL 2005-1 (PU E COUNTY DISTRICTE~OWITH THE RIV~~i~~S DOCUME~TA~~ OF
RECO~DON NOVEMBER ~ PAGES 71 -77, 0; DISTRICTS. OFFIC 134 IN BOOK 6 , NITY FACILITIE 2005-0804 NT AND COMMU ND DEEDS OF
ASSESSME O THE MAPS A E COUNTY
HEREBY MADE T SSESSOR OF TH HE LINES
REFER~Nl~ET~E OFFICE o,:iL~~E ;ESCR IPTli~~;EiN . THOSE ~~~~:1~~~~1~~~'6~ ~~OTY ::~(~~~A~~s06'L~N~!~~ l~1°R6~~ AND D GOVERN F CH PARCE · MAPS SHAL~IMENSIONS OF SB~ ITS DISTINCTIVE
LIN~~t~~ IED IN SAID ~~~~E R {APN). IS I SOR'S PARCEL ASSES MAP NO. 28 OF 2005-1
ANNE~iL~~ES DISTRI~~ Nc°ouNTY OF
coMMUN~JT~ SERVICES) 0{AIIFORNIA (PUBLIC SA RSIDE STATE OF RIVE '
EXHIBIT B
TRACT MAPS OF THE PROPOSED ANNEXATION TERRITORY
CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2005-1
(PUBLIC SAFETY SERVICES)
ANNEXATION NO. 28
SERENA PARK, TRACTS
39025, 36691-1, 36691-2, 36691-3,
36691-4, 36691-5, 36691-6, 36691
Item 1H - Page 10
Item 1H - Page 11
EASEMENT NOTES:
.1. E.~"E :;..==v.: ' % :-..::::-- •
Li, =-···---~-7:. ---.:..
& ~.i.S'?.f:."':o:=::ilr'.,_-=.-::,:.:A
.'.!. --·-- ··==,:,.-,.,:_
.'.!. ---¾F-- ,,,.,__..,,....,_..,,..:::r.
& *..a=:-:!="..;;s-:s-z..:;;:e..=-::=-·
& ; :.:::::::= ::.-:-...::::-:::::.-:-..:,.-=----=
& ; ::::::.--; ;: :.:.-:= :_-:..-:-.. -
& -- :..-:-.::=-= ..... ===•·
8 ==~-=-~ ·::-==-""='S:.-=---
£ ----~--- -·--·-·-·
8 !:="'?"..=="".:.~-E:".:! • -=--
& ---·-- --=---=-..... ~.-
8 --------=-=--==•--::,:.
& ::5Er-i~n;:"..~.::::.~-:-..:;.--
8 --·--•·=--===·
& ~~-==~.,;?5-~.!£-
SERENA 386, LLC
2392 MORSE.AVE
fRVIHE. CA 112614
(949/m"""'°
U:G<OCSC!111'11CW,
NOT A PART OF
THIS SUBOMSION
AREA• 19.97 oc.
'1
A POROON C£ rHf SOU!H /ilil.F CF SCCTVN .36.
tO'tlN5HP J SCt.lffl, RAM;£. 4 WT, S.l;l.W. MIO
(T 11£ NOmOST OUMUfR (Y sa:ooN /,
Tr.lllNSHP • $(XJTH. RAJ-a 4 CA.ST, S.8..v.
~
,,
'¢',;:,
' " ' ' ' ' ',._
'
'
>
r
I'
I
I
I
I
L
'
"
~
' '
' ~
' ' ' ..,~ ' ' ·~ '
SEE SHEET 2
INDEX MAP
15230 Burbank BIYd
Van Nuys. CA 9 1411
Tel (818) 787-8550
Fax (8181 901-745 1
1nlo4'111kaod com
r
VICI NITY MAP
ASSF'.SSOR PA8C£1 NJIMBE'.RS·
CM.OIQNE8'-DD<Cil€DINC~IDI
:.,:x'~,~ ~-.rn:•oo
P<OI£: (61&}-717--eMG
~YDUNC,~ln»J
l>l'D $UIM'.ll')I: -D (MGH'.{J!NC -.a..JU
,,n, -lll'°-s,,nr ,oo ._...,,,_Ql, 1~11
~~~)~~:
GENERAL NOTES·
~lNIDZOoll:{ O • OSJ
"""""'°OC\oU-OIST!!ICl .. l i&JOl"OtWCll:
OOSTINCl«-.,._,.,I.JM..., <ftNV,,,Cl - ™NIIUIJIU, -(Ol-"fl'J ~Ul~-Vrt<l'-"C: "lJfflOIIIOOl'51ITIIUl;IOll"llll(',\l:ft) l'QIAl,..._,,O,wr, •
--
c-)•1'-XIO!l
<- ) <&J-5CCIO
<-}U~ - •UI
O'C) l00- 1) 1?
('NC) J;!.J- l lM
• 'flltOlllOCf\llUIES'l"IIU'l . ~"'5A~5"lll:l . 1Hl:I.OTS l'fteftlm"mlD1"WODOl"--rT "-'Ir• CDM:rtllMaiE UNII
N-«Ji:wo,1::111£~'1111IO.IIMTIIOIIIICTOl~MIDMl:1ftl
JG;;J!NIJ;
- --- -,-~ ---,,,r;,,,cr.., r
----£A1DIOI T
--- CPifDJU(C
TENTATIVE TRACT MAP NO. 39025
IN THE CITY OF PALM SPRINGS
COUNTY OF RIVERSIDE , STA TE OF CALIFORNIA
Item 1H - Page 12
NOT A PART OF
THIS SU8Dl\.1SION
REMAINDER PARCEL
AREA - 24.94 OC.
LEGEND,
----- r~.e~ __ .-ru..,~
TENTATIVE TRACT MAP NO. 39025
IN THE CITY OF PALM SPRINGS
COUNTY OF RIVERSIDE, STATE OF CALIFORNIA
EXHIBIT C
LIST OF PARTICIPATING ASSESSOR’S PARCELS
CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2007-1
(PUBLIC SAFETY SERVICES)
ANNEXATION NO. 28 SERENA PARK,
TRACT #’s 39025, 36691-1, 36691-2, 36691-3,
36691-4, 36691-5, 36691-6, 36691
APN ACRES LANDOWNER
501-190-011 84.61 SERENA 386
501-190-014 35.65 SERENA 386
669-480-027 33.72 SERENA 386
669-590-066 0.26 SERENA 386
Item 1H - Page 13
EXHIBIT D
RATE AND METHOD OF APPORTIONMENT
CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2005-1
(PUBLIC SAFETY SERVICES)
A Special Tax of Community Facilities District No. 2005-1 (Public Safety Services) of the City of Palm Springs (the “District”) shall be levied on all Assessor’s Parcels in the District and collected each Fiscal Year commencing in Fiscal Year 2006 -07 in an amount determined by the City through the application of the rate and method of apportionment of the Special Tax set forth below. All of the real property in the District, unless exempted by law or by the provisions hereof, shall be taxed for the purposes, to the extent and in the manner herein provided.
A. DEFINITIONS
The terms hereinafter set forth have the following meanings:
“Acre of Acreage” means the land area of an Assessor’s Parcel as shown on an Assessor’s Parcel Map, or if the land area is not shown on an Assessor’s Parcel Map, the land area shown on the applicable final subdivision map, other final map, other parcel map, other condominiu m plan, or functionally equivalent map or instrument recorded in the Office of the County Recorder. The square footage of an Assessor’s Parcel is equal to the Acreage multiplied by 43,560.
“Act” means the Mello-Roos Community Facilities Act of 1982, being Chapter 2.5, Part 1, Division 2 of Title 5 of the Government Code of the State of California, as amended, which authorizes the establishment of the District to finance: a) police protection services, and b) fire protection and suppression services, and life safety services including but not limited to ambulance and paramedic services.
“Administrative Expenses” means the actual or estimated costs incurred by the City as administrator of the District to determine, levy and collect the Special Taxes, including the proportionate amount of the salaries and benefits of City employees whose duties are directly related to administration of the District and the fees of consultants, legal counsel, the costs of collecting installments of the Special Taxes upon the general tax rolls, preparation of required reports; and any other costs required to administer the District as determined by the City.
“Annual Escalation Factor” means the greater of the increase in the annual percentage change of the All Urban Consumers Consumer Price Index (CPI) or the percent increase of salaries and benefits for public safety employees as stated in the Memorandum of Understanding for the fiscal year of the Special Tax. The annual CPI used shall be for the area of Los Angeles-Riverside- Orange County, CA as reflected in the then-current April Item 1H - Page 14
update. The annual CPI used shall be as determined by the United States Department of Labor, Bureau of Labor Statistics, and may be obtained through the California Division of Labor Statistics and Research ( www.dir.ca.gov/dlsr). If the foregoing index is not available, the District Administrator shall select a reasonably comparable index.
“Assessor’s Parcel” means a lot or parcel shown in an Assessor’s Parcel Map with an assigned assessor’s parcel number.
“Assessor’s Parcel Map” means an official map of the Assessor of the County designating parcels by assessor’s parcel number.
“Base Year” means Fiscal Year ending June 30, 2007.
“BIA” means the Bureau of Indian Affairs within the Department of the Interior and any tribe acting on behalf of the BIA.
“City” means the City of Palm Springs.
“Council” means the City Council of the City of Palm Springs, acting as the legislative body of the District.
“County” means the County of Riverside, California.
“Developed Multi-Family Residence” means an Assessor’s Parcel of Developed Property for which a building permit has been issued for purposes of constructing a residential structure consisting of more than one residential Dwelling Unit which share common walls, including, but not limited to, duplexes, triplexes, town homes, condominiums, and apartment units.
“Developed Property” means all Taxable Property, exclusive of Property Owner Association Property, Non-Residential Property, or Public Property, for which a building permit was issued after January 1, 2006 and prior to May 1st preceding the Fiscal Year in which the Special Tax is being levied.
“Developed Single-Family Residence” means an Assessor’s Parcel of Developed Property for which a building permit(s) has been issued for purposes of constructing one single-family residential Dwelling Unit.
“District Administrator” means an official of the City, or designee thereof, responsible for determining the Special Tax Requirement and providing for the levy and collection of the Special Taxes.
“District” means Community Facilities District No. 2005-1 (Public Safety Services) of the City of Palm Springs.
“Dwelling Unit” means any separate residential unit in which a person or persons may Item 1H - Page 15
live, which includes provisions for sleeping, cooking and sanitation, and is not considered to be for commercial or industrial use.
“Entitled Property” means an Assessor’s Parcel and/or Lot in the District, which has a Final Map recorded prior to January 1 st preceding the Fiscal Year in which the Special Tax is being levied, but for which no building permit has been issued prior to the May 1st preceding the Fiscal Year in which the Special Tax is being levied. The term “Entitled Property” shall apply only to Assessors’ Parcels and/or Lots, which have been subdivided for the purpose of residential development, excluding any Assessor’s Parcel that is designated as a remainder parcel determined by final documents and/or maps available to the District Administrator.
“Final Map” means an Assessor’s Parcel Map, a final subdivision map, other parcel map, other final map, other condominium plan, or functionally equivalent map that has been recorded in the Office of the County Recorder.
“Fiscal Year” means the period starting July 1 and ending on the following June 30.
“Land Use Class” means any of the classes listed in Table 1.
“Lot” means property within a recorded Final Map identified by a lot number for which a building permit has been issued or may be issued.
“Maximum Special Tax” means the maximum Special Tax, determined in accordance with Section C below that can be levied in the District in any Fiscal Year on any Assessor’s Parcel.
“Non-Residential Property” means all Assessors’ Parcels for which a building permit(s) has been issued for a non-residential used and does not contain any residential units as defined under Developed Single Family Residence or Developed Multi-Family Residence.
“Property Owner Association Property” means any property within the boundaries of the District that is owned by or irrevocably dedicated as indicated in an instrument recorded with the County Recorder to a property owner association, including any master or sub-association.
“Proportionately” means in a manner such that the ration of the actual Special Tax levy to the Maximum Special Tax is equal for all Assessor’s Parcels within each Land Use Class.
“Public Property” means any property within the boundaries of the District that is, at the time of the District formation or at the time of an annexation, expected to be used for rights- of-way, parks, schools or any other public purpose and is owned by or irrevocably offered for dedication to the federal government, the State, the County, the City or any other public agency.
Item 1H - Page 16
“Public Safety Service Costs” means the estimated and reasonable costs of providing police services and fire protection and suppression services and life safety services, including but not limited to (i) the costs of contracting services, (ii) equipment, vehicles, ambulances, and paramedics, fire apparatus, supplies, (iii) the salaries and benefits of City staff that directly provide police services and fire protection and suppression services and life safety services, respectively, and (iv) City overhead costs associated with providing such services within the District. On each July 1 following the Base Year the increases attributed to salaries and benefits shall be calculated and limited to the increase based on the Annual Escalation Factor. The Special Tax provides only partial funding for police, fire and life safety services.
“Special Tax” means the Special Tax to be levied in each Fiscal Year on each Assessor’s Parcel of Taxable Property to fund the Special Tax Requirement, and shall include Special Taxes levied or to be levied under Sections C and D, below.
“Special Tax Requirement” means that amount required in any Fiscal Year for the District to: (i) pay for Public Safety Service Costs; (ii) pay reasonable Administrative Expenses; (iii) pay any amounts required to establish or replenish any reserve funds; and (iv) pay for reasonably anticipated delinquent Special Taxes based on the delinquency rate for Special Taxes levied in the previous Fiscal Year; less any surplus of funds available from the previous Fiscal Year’s Special Tax levy.
“State” means the State of California.
“Taxable Property” means all of the Assessor’s Parcels within the boundaries of the District and any future annexation to the District that are not exempt from the Special Tax pursuant to law or as defined herein.
“Tax-Exempt Property” means an Assessor’s Parcel not subject to the Special Tax.
Tax- Exempt Property includes: (i) Public Property, (ii) Property Owner Association Property, (iii) Non- Residential Property, and (iv) property designated by the City or District Administrator as Tax- Exempt Property.
“Undeveloped Property” means, for each Fiscal year, all Assessor’s Parcels of Taxable Property not classified as Developed Property or Entitled Property, including an Assessor’s Parcel that is designated as a remainder parcel and is not identified as potential Public Property by any final documents and/or maps available to the District Administrator.
“Unit” means any separate residential dwelling unit in which a person or persons may live, which comprises an independent facility capable of conveyance separate from adjacent residential dwelling units and is not considered to be for commercial or industrial use.
Item 1H - Page 17
B. ASSIGNMENT TO LAND USE CATEGORIES
Each Fiscal Year using the definitions above, all property within the District shall be classified as either Developed Property or Tax -Exempt Property. Developed Property shall be further classified as Developed Single -Family Residence or Developed Multi - Family Residence. Commencing with the Base Year and for each subsequent Fiscal Year, all Developed Property shall be subject to Special Taxes pursuant to Sections C and D below.
C. MAXIMUM SPECIAL TAX RATE
1. Developed Property
TABLE 1
Maximum Special Tax for Developed Property
Community Facilities District No. 2005-1
(Public Safety Services)
Land Use
Class Description
Maximum
Special Tax
1 Developed Single-Family
Residence $350 per Dwelling Unit
2 Developed Multi-Family
Residence $295 per Dwelling Unit
On each July 1 following the Base Year (i.e., July 1, 2007), the Maximum Special Tax Rates in Table 1 shall be increased in accordance with the Annual Escalation Factor. Once the Maximum Special Tax per Dwelling Unit is equal to $500 per Dwelling Unit, no further Annual Escalation Factor shall be applied and the Maximum Special Tax per Dwelling Unit shall not exceed $500.
2. Entitled Property
Table 2
Maximum Special Tax for Entitled Property
Community Facilities District No. 2005-1
(Public Safety Services)
Land Use Class
Description
Maximum Special Tax
Per Lot
3 Entitled Property $100 per Lot
No Annual Escalation Factor shall be applied to the Maximum Special Tax per Lot for Entitled Property.
Item 1H - Page 18
3. Undeveloped Property
Undeveloped Property will be assigned a Maximum Special Tax Rate of $500 per Acre or portion thereof, with a minimum rate of $100 for Undeveloped Property less than or equal to one-fourth (1/4) of an Acre as described in Table
3. Table 3
Maximum Special Tax for Undeveloped Property
Community Facilities District No. 2005-1
(Public Safety Services)
Land Use
Class
Description
Maximum Special
Tax Per Parcel/Acre
4 Undeveloped Property less than
or equal to ¼ Acre
$100 per
Assessor’s Parcel
5 Undeveloped Property > ¼ Acre
$500 per Acre
No Annual Escalation Factor shall be applied to the Maximum Special Tax per Parcel/Acre for Undeveloped Property.
4. Tax-Exempt Property
No Special Tax shall be levied on Tax-Exempt Property.
5. Multiple Land Use Classes
In some instances, an Assessor’s Parcel may contain more than one Land Use Class. The Maximum Special Tax levied on an Assessor’s Parcel shall be the sum of the Maximum Special Tax levies that can be imposed on all Land Use Classes located on that Assessor’s Parcel.
D. METHOD OF APPORTIONMENT OF THE SPECIAL TAX
Commencing with Fiscal Year 2006-07, and for each subsequent Fiscal Year, the District Administrator shall calculate the Special Tax Requirement based on the definitions in Section A and levy the Special Tax as follows until the amount of the Special Tax levied equals the Special Tax Requirement. First, the Special Tax shall be levied each Fiscal Year on each Assessor’s Parcel of Developed Property Proportionately between Developed Single-Family Residence and Developed Multi-Family Residence up to 100% of the applicable Maximum Special Tax. Second, if the Special Tax Requirement has not Item 1H - Page 19
been satisfied by the first step, then the Special Tax shall be levied each Fiscal Year on each Assessor’s Parcel of Entitled Property up to 100% of the applicable Maximum Special Tax for Entitled Property. Lastly, if the first two steps have not satisfied the Special Tax Requirement, then the Special Tax shall be levied each Fiscal Year on each Assessor’s Parcel of Undeveloped Property up to 100% of the applicable Maximum Special Tax for Undeveloped Property.
E. APPEALS
Any tax payer that believes that the amount of the Special Tax assigned to an Assessor’s Parcel is in error may file a written notice with the District Administrator appealing the levy of the Special Tax. This notice is required to be filed with the District Administrator during the Fiscal Year the error is believed to have occurred. The District Administrator or designee will then promptly review the appeal and, if necessary, meet with the taxpayer.
If the District Administrator verifies that the tax should be changed the Special Tax Levy shall be corrected and, if applicable in any case, a refund shall be granted.
F. EXEMPTIONS
1. Residential Property
Residential Properties which annually meet one or more of the following standards shall be exempt from payment of the Special Tax:
a. A Residential Property consisting of one or two person(s) earning $15,300 or less gross income per year, upon complying with procedures to establish such exemption, or
b. A Residential Property consisting of three persons earning $17,900 or less gross income per year, upon complying with procedures to establish such exemption, or
c. A Residential Property which qualifies for either the Low Income Rate Assistance (LIRA) exemption for electrical or gas services or the Lifeline exemption for telephone services.
The City is authorized and directed to promulgate administrative rules and procedures for verification of eligibility for the exemptions referred to in section F.
G. MANNER OF COLLECTION
Special Tax as levied pursuant to Section D above shall be collected in the same manner and at the same time as ordinary ad valorem property taxes; provided, however, that the District Administrator may directly bill the Special Tax, many collect Special Taxes at a different time or in a different manner if necessary to meet the financial obligations of the District or as otherwise determined appropriate by the District Administrator.
Item 1H - Page 20
H. TERM OF SPECIAL TAX
Every Five years after the establishment of the District, the City Council may reexamine, if deemed necessary by City Council, the necessity of the continuance of the Special Tax through the preparation of a Fiscal Impact Analysis, otherwise the Special Tax shall be levied in perpetuity.
Item 1H - Page 21
EXHIBIT E
NOTICE OF PUBLIC HEARING
Notice is hereby given that the City Council of the City of Palm Springs will conduct a public hearing on Wednesday, May 14, 2025, at 5:30 p.m. or as soon thereafter as the matter may be heard, in the City Council Chambers located at 3200 East Tahquitz Canyon Way, Palm Springs, California, 92262, to consider the following:
CITY OF PALM SPRINGS
COMMUNITY FACILITIES DISTRICT NO. 2005-1
(PUBLIC SAFETY SERVICES)
SERENA PARK, TRACTS
39025, 36691-1, 36691-2, 36691-3,
36691-4, 36691-5, 36691-6, 36691
On March 27, 2025, the City Council, as the legislative body for the District, adopted a resolution entitled " A Resolution Of The City Council Of The City Of Palm Springs, California, Declaring Its Intention To Annex Territory Into A Community Facilities District To Authorize The Levy Of Special Taxes " (the " ROI"). Pursuant to the ROI, the City Council determined that the public convenience and necessity require that certain territory, as more particularly described in the ROI, be annexed to the existing District, all as provided in the Mello -Roos Community Facilities Act of 1982 (Sections 53311 and following, California Government Code) (the "Act"). Reference is hereby made to the ROI, on file with the City Clerk of the City for further particulars. The following is a summary of the provisions of the ROI.
In the ROI, the City Council declared its intention to annex territory into Community Facilities District No. 2005-1 (Public Safety Services) (the "District"). The area proposed to be annexed to the District is as shown on Annexation Map No. 28, on file with the City Clerk, and identified in Exhibit A of the ROI. The District shall fund police services, fire protection and suppression services, and life safety services. It is presently intended that the services will be provided, without preference or priority, to the existing territory in the District and the territory proposed to be annexed to the District. The ROI provides that the special taxes heretofore caused to be levied in the District shall be levied in the territory proposed to be annexed, subject to public hearing and owner consent proceedings as specified in the Act.
At the public hearing the testimony of all interested persons for and against the annexation of said territory to the District or the levying of special taxes within the territory proposed to be annexed will be heard. Any person interested may file a protest in writing with the City Clerk.
Isl Brenda Pree
City Clerk
City of Palm Springs
Item 1H - Page 22
CITY COUNCIL STAFF REPORT
DATE: MARCH 27, 2025 CONSENT CALENDAR
SUBJECT: ACCEPTANCE OF OUTDOOR EXERCISE EQUIPMENT INSTALLATION
AND SURFACING IMPROVEMENTS AT DESERT HIGHLAND PARK
FROM: Scott C. Stiles, City Manager
BY: Nicholas S. Gonzalez, Director of Parks & Recreation
SUMMARY:
Formal City Council acceptance of the outdoor exercise equipment installation at Desert Highland Park (the “Project”) is required to document the completion of public works improvements and to allow the City’s filing of a Notice of Completion with the Riverside County Recorder in accordance with Section 9200 of the California Civil Code.
RECOMMENDATION:
1) Accept the public works improvement identified as Desert Highland Park Surfacing Improvements, as completed in accordance with the Construction Contract; 24C253.
2) Authorize the Director of Parks & Recreation to execute and file for recordation with the Riverside County Recorder a Notice of Completion ( Attachment A) for Desert Highland Park Surfacing Improvements project.
3) Accept the public works improvement identified as Desert Highland Park Exercise Equipment Purchase and Installation, as completed in accordance with the Construction Contract; 24I283.
4) Authorize the Director of P arks & Recreation to execute and file for recordation with the Riverside County Recorder a Notice of Completion ( Attachment B) for Desert Highland Park Exercise Equipment Purchase and Installation.
BUSINESS PRINCIPAL DISCLOSURE:
According to the Public Integrity Disclosure form ( Attachment C), Miracle Recreation Equipment Company is a corporation registered in the state of Missouri; and Playcore Wisconsin, Inc., dba GameTime is a corporation registered in the state of Alabama (Attachment D).
Item 1I - Page 1
City Council Staff Report
March 27, 2025 -- Page 2
Acceptance of Outdoor Exercise Equipment Installation – Desert Highland Park
BACKGROUND:
In FY 2021-2022, the Measure J Commission approved an application for a Community Initiated project to purchase and install exercise equipment at Desert Highland Park.
The Parks and Recreation Commission reviewed the Project as recommended by Measure J on December 18, 2023, and directed staff to move forward with the project , and to seek out additional improvements to enhance the experience by incorporating rubber surfacing and concrete curbing for each installation.
In December of 2023 , Parks & Recreation staff met with the Desert Highland Gateway Estates Community Action Association to develop a list of desired outdoor exercise equipment along with a list of preferred locations. Following the finalization of the exercise equipment locations, staff solicited quotes through cooperative purchasing vendors and obtained three quotes for the purchase and installation of equipment.
On November 7, 2024, the City Manager approved Construction Contract 24I283 (Attachment E) with Playcore Wisconsin, Inc., dba Game Time to purchase and install outdoor exercise equipment at Desert Highland Park for an amount not to exceed $69,032.38.
On October 1 7, 202 4, the City Manager approved Construction Contract 24C253 (Attachment F ) with Miracle Recreation Equipment Company, to provide surfacing improvements including the installation of rubberized surfacing and concrete curbing for the outdoor exercise equipment sites at Desert Highland Park for an amount not to exceed $79,662.
STAFF ANALYSIS:
Following the approval of Construction Contract 24I283, a notice to proceed was issued identifying a start date of November 7, 2024.
Construction of the Desert Highland Park Exercise Equipment Purchase and Installation Project began on January 13, 2025, with the installation of eleven (11) pieces of exercise equipment by Playcore Wisconsin, Inc., dba GameTime and was determined to be substantially completed on January 31, 2025.
Following the approval of Construction Contract 24C253, a notice to proceed was issued identifying a start date of December 3, 2024.
During construction, on February 4, 2025, staff identified that vandalism damages had occurred and required rubber surfacing to be replaced at five (5) of the eleven (11) pieces of exercise equipment, initiating Contract Change Order No. 1 ( Attachment G) in the amount of $5,000 for the removal and installation of approximately 530 square feet of rubberized surfacing, for a revised contract amount not to exceed $84,662.
Item 1I - Page 2
City Council Staff Report
March 27, 2025 -- Page 3
Acceptance of Outdoor Exercise Equipment Installation – Desert Highland Park
Construction of the Desert Highland Park Surfacing Improvements Project began on February 3, 2025, and was determined to be substantially completed on February 11, 2025.
Staff recommends that City Council accept the Project s as required by Section 9200 of the California Civil Code and authorize the Director of Parks & Recreation to file and record Notice of Completions to be submitted to the County.
ENVIRONMENTAL ASSESSMENT
:
In accordance with the California Environmental Quality Act (“CEQA”) Guidelines Section 15301 “Existing Facilities”, Class 1 projects consist of the operation, repair, maintenance, permitting, leasing, licensing, or minor alteration of existing public structures, facilities, mechanical equipment or topographical features involving negligible or no expansion of existing or former use. Therefore, Staff has determined that the subject Project, is considered categorically exempt from CEQA.
ALIGNMENT WITH STRATEGIC PLANNING:
Approval of this action supports City Council priority 2, Community Infrastructure.
FISCAL IMPACT:
The original contract amount for Desert Highland Park Exercise Equipment Purchase and Installation Construction Contract 24I283 was $69,032.38. The City is currently holding retention in the amount of $3,451.62 (5%), for Playcore Wisconsin Inc., dba GameTime pending the acceptance of improvements and filing of the Notice of Completion with the County Recorder’s Office.
The original contract amount for Desert Highland Park Surfacing Improvements Construction Contract 24C253 was $79,662, and throughout the duration of the project the City entered into one contract change order for a total increase of $5,000, and a final construction cost of $ 84,662. The City is currently holding retention in the amount of $4,233.10 (5%), pending the acceptance of improvements and filing of the Notice of Completion with the County Recorder’s Office.
REVIEWED BY:
Director of Parks & Recreation: Nicholas S. Gonzalez
Acting Procurement & Contracting Manager: Tabitha Richards Assistant City Manager: Teresa Gallavan
City Manager: Scott Stiles
Item 1I - Page 3
City Council Staff Report
March 27, 2025 -- Page 4
Acceptance of Outdoor Exercise Equipment Installation – Desert Highland Park
ATTACHMENTS:
A. Notice of Completion 24C253
B. Notice of Completion 24I283
C. Public Integrity Disclosure Miracle Recreation Equipment Company D. Public Integrity Disclosure Playcore Wisconsin, Inc., dba Game Time E. Construction Contract 24I283
F. Construction Contract 24C253
G. Contract Change Order 1
Item 1I - Page 4
ATTACHMENT A
Item 1I - Page 5
Name
Street
Address
City &
State
SPACE ABOVE THIS LINE FOR RECORDERS USE
NOTICE OF COMPLETION
(CA Civil Code §§ 8180-8190, 8100-8118, 9200-9208)
NOTICE IS HEREBY GIVEN THAT:
1. The undersigned is an owner of an interest of estate in the hereinafter described real property, the nature of which interest or estate is:
_________________________________________________________________________________ (e.g. fee, leasehold, joint tenancy , etc.)
2. The full name and address of the undersigned owner or reputed owner and of all co -owners or reputed co -owners are:
Name Street and No. City State
__________________________________________________________________________________________________________
3. The name and address of the direct contractor for the work of improvement as a whole is:
__________________________________________________________________________________________________________
4. This notice is given for (check one):
Completion of the work of improvement as a whole.
Completion of a contract for a particular portion of the work of improvement (per CA Civ. Code § 8186).
5. If this notice is given only of completion of a contract for a particular portion of the work of improvement (as provided in CA Civ. Code § 8186), the name and address of the direct contractor under that contract is:
___________________________________________________________________________________________________________
6. The name and address of the construction lender, if any, is:
___________________________________________________________________________________________________________
7. On the ____________ day of ___________, 20___, there was completed upon the herei n described property a work of improvement as a whole (or a particular portion of the work of improvement as provided in CA Civ. Code § 8186) a general description of the work provided:
___________________________________________________________________________________________________________
8. The real property herein referred to is situated in the City of __________________________, County of _______________________ _ State of California, and is described as follows:
___________________________________________________________________________________________________________
9. The street address of said property is:
___________________________________________________________________________________________________________
10. If this Notice of Completion is signed by the owner’s successor in interest, the name and address of the successor’s transferor is:
___________________________________________________________________________________________________________ I certify (or declare) under pe nalty of perjury under the laws of the State of California that the foregoing is true and correct.
Date: _______________________________________ By: ________________________________________________________ Signature of Owner or Owner’s Authorized Agent
City of Palm Springs
Recording Requested By:
When Recorded Mail To:
Item 1I - Page 6
VERIFICATION
I, _______________________________________________, state: I am the ________________________________ __ (“Owner∫, “President”, “Authorized
Agent”, “Partner”, etc.) o
f the Owner identified in the foregoing Notice of Completion. I have read said Notice of Completion and know the contents thereof; the same is true of my own knowledge.
I decl
are under penalty of perjury under the laws of the State of California that the foregoing is true and correct.
Executed on _______________________, _______ (date) , at _______________________________________________ ______ (City), ________ (State). ______________________________________________________
Signature of Owner or Owner’s Authorized Agen
David McAbee: Director of Public Works
City of Palm Springs
PROOF OF SERVICE DECLARATION
a.
b.
c.
_____________________________________________________________ (Signature of Person Making Service)
STATE OF CALIFORNIA
COUNTY OF ______________________________________
On _____________________________ ____________, ________ (date), before me, ________________________________ ____________, Notary Public (name and title of officer) personally appeared __________________________________________who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorize d capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
I certify under PENALTY OF PURJURY under the laws of the State of California that the foregoing paragraph is true and correct.
Witness my hand and official seal.
_____________________________________________
Signature
A Notary Public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.
Item 1I - Page 7
ATTACHMENT B
Item 1I - Page 8
Name
Street
Address
City &
State
SPACE ABOVE THIS LINE FOR RECORDERS USE
NOTICE OF COMPLETION
(CA Civil Code §§ 8180-8190, 8100-8118, 9200-9208)
NOTICE IS HEREBY GIVEN THAT:
1. The undersigned is an owner of an interest of estate in the hereinafter described real property, the nature of which interest or estate is:
_________________________________________________________________________________ (e.g. fee, leasehold, joint tenancy , etc.)
2. The full name and address of the undersigned owner or reputed owner and of all co -owners or reputed co -owners are:
Name Street and No. City State
__________________________________________________________________________________________________________
3. The name and address of the direct contractor for the work of improvement as a whole is:
__________________________________________________________________________________________________________
4. This notice is given for (check one):
Completion of the work of improvement as a whole.
Completion of a contract for a particular portion of the work of improvement (per CA Civ. Code § 8186).
5. If this notice is given only of completion of a contract for a particular portion of the work of improvement (as provided in CA Civ. Code § 8186), the name and address of the direct contractor under that contract is:
___________________________________________________________________________________________________________
6. The name and address of the construction lender, if any, is:
___________________________________________________________________________________________________________
7. On the ____________ day of ___________, 20___, there was completed upon the herei n described property a work of improvement as a whole (or a particular portion of the work of improvement as provided in CA Civ. Code § 8186) a general description of the work provided:
___________________________________________________________________________________________________________
8. The real property herein referred to is situated in the City of __________________________, County of _______________________ _ State of California, and is described as follows:
___________________________________________________________________________________________________________
9. The street address of said property is:
___________________________________________________________________________________________________________
10. If this Notice of Completion is signed by the owner’s successor in interest, the name and address of the successor’s transferor is:
___________________________________________________________________________________________________________ I certify (or declare) under pe nalty of perjury under the laws of the State of California that the foregoing is true and correct.
Date: _______________________________________ By: ________________________________________________________ Signature of Owner or Owner’s Authorized Agent
City of Palm Springs
Recording Requested By:
When Recorded Mail To:
Item 1I - Page 9
VERIFICATION
I, _______________________________________________, state: I am the ________________________________ __ (“Owner∫, “President”, “Authorized
Agent”, “Partner”, etc.) o
f the Owner identified in the foregoing Notice of Completion. I have read said Notice of Completion and know the contents thereof; the same is true of my own knowledge.
I decl
are under penalty of perjury under the laws of the State of California that the foregoing is true and correct.
Executed on _______________________, _______ (date) , at _______________________________________________ ______ (City), ________ (State). ______________________________________________________
Signature of Owner or Owner’s Authorized Agen
David McAbee: Director of Public Works
City of Palm Springs
PROOF OF SERVICE DECLARATION
a.
b.
c.
_____________________________________________________________ (Signature of Person Making Service)
STATE OF CALIFORNIA
COUNTY OF ______________________________________
On _____________________________ ____________, ________ (date), before me, ________________________________ ____________, Notary Public (name and title of officer) personally appeared __________________________________________who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorize d capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
I certify under PENALTY OF PURJURY under the laws of the State of California that the foregoing paragraph is true and correct.
Witness my hand and official seal.
_____________________________________________
Signature
A Notary Public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.
Item 1I - Page 10
ATTACHMENT C
Item 1I - Page 11
Item 1I - Page 12
Who Must File?
CITY OF PALM SPRINGS
PUBLIC INTEGRITY DISCLOSURE
(INSTRUCTIONS FOR APPLICANTS)
Applicants that are NOT a natural person or group of natural people that will be identified on the application, and seek a City approval determined by a vote of City officials. Examples include corporations, limited liability companies, trusts, etc. that seek a City Council approval, or an approval by one of the City's board or commissions.
Why Must I File?
The City of Palm Springs Public Integrity Ordinance advances transparency in municipal government and assists public officials in avoiding conflicts of interest. The City's Public Integrity Ordinance, codified in Chapter 2.60 of the municipal code, reflects the City's interest in ensuring that companies (and other legal entities that are not natural people) doing business in the community are transparent and make disclosure as to their ownership and management, and further that those companies disclose the identity of any person, with an ownership interest worth two thousand dollars ($2,000) or more, who has a material financial relationship with any elected or appointed voting City official, or with the City Manager or City Attorney.
Note: A material financial relationship is a relationship between someone who is an owner/investor in the applicant entity and a voting official (or the City Manager or City Attorney), which relationship includes any of the following:
(1) the owner/investor and the official have done business together during the year prior to the application;
(2) the official has earned income from the owner/investor during the year prior to the filing of the application;
(3) the owner/investor has given the official gifts worth fifty dollars ($50) or more during the year prior to the filing of the application; or
(4) the official might reasonably be anticipated to gain or lose money or a thing of value, based upon the owner/investor's interest in the applicant entity, in relation to the application's outcome.
When Must I File?
You must file this form with the Office of the City Clerk at the same time when you file your application for a City approval determined by a vote of City officials, whether elected or appointed.
(Revised 09 13 18)
CITY OF PALM SPRINGS -PUBLIC INTEGRITY DISCLOSURE
(INSTRUCTION FOR APPLICANTS)
Item 1I - Page 13
What Must I Disclose?
A. The names of all natural persons who are officers, directors, members, managers, trustees, and other fiduciaries serving trusts or other types of organizations (attorneys, accountants, etc.).
Note: (1} only trusts or other organizations that are not the fiduciaries, (2) if a second entity that is not a natural person seNes the applicant entity (e.g., as a member of an applicant LLCJ, then all officers, directors, members, managers, trustees, etc., of the second entity must be disclosed).
8. The names of persons owning an interest with a value of two thousand dollars ($2,000) or more who have a material financial relationship with an elected or appointed City official who will vote on the applicant's application, or with the City Manager or City Attorney.
PENALTIES
Falsification of information or failure to report information required to be reported may subject you to administrative action by the City.
(Revised 09 13 18)
CITY OF PALM SPRINGS-PUBLIC INTEGRITY DISCLOSURE
(INSTRUCTION FOR APPLICANTS)
Item 1I - Page 14
1. 2.
3. 4.
Name of Entity
PUBLIC INTEGRITY DISCLOSURE
APPLICANT DISCLOSURE FORM
/l;} ;lf,Ja., R~Lr<~iM
Address of Entity (Principle Plac
Local or California Address (if di
J1A
State where Entity is Registered with Secretary of State ra~
6. Type of Entity
g,6c,rporation O Limited Liability Company D Partnership D Trust D Other (please specify)
6. Officers, Directors, Members, Managers, Trustees, Other Fiduciaries (please specify) Note: If any response is not a natural person, please identify all officers, directors, members, managers and other fiduciaries for the member, manager, trust or other entity _£_ ... ~ .... ·-· ........ _1/+-\=q.,_'1-;=-----J->-• _________ ~er D Director D Member O Manager ---r----" / [name]
D General Partner D Limited Partner
Other ____________ _
_ fr_L.3'<{j(_'---M ____ g....__('--r"-'' V\--'-\4:-__ r _______ [IJ)tfker Director Member Manager [name]
D General Partner D Limited Partner
Other ____________ _
-~~---'-..;;;.W_\l\....:..._W=--:Jl~--=-l-4~Ge___;_f'=-----------~er D Director D Member D Manager [name]
(Revised 09 13 18)
D General Partner D Limited Partner
Other ____________ _
CITY OF PALM SPRINGS -PUBLIC INTEGRITY DISCLOSURE
APPLICANT DISCLOSURE FORM
Item 1I - Page 15
7. Owners/Investors with a 5% beneficial interest in the Annlicant Entitv or a related entitv
EXAMPLE
JANE DOE 50%, ABC COMPANY, Inc.
[name of owner/investor] [percentage of beneficial interest in entity and name of entitvl
A.
Ql~~1t.1!£ . lOO io
a7of owner/investor] [percentage of beneficial interest in entity
and name of entitvl
B.
[name of owner/investor] [percentage of beneficial interest in entity
and name of entitvl
C.
[name of owner/investor] [percentage of beneficial interest in entity
and name of entitvl
0. [name of owner/investor] [percentage of beneficial interest in entity
and name of entitvl
E.
[name of owner/investor] [percentage of beneficial interest in entity and name of entitvl
I DECLARE UNDER PENALTY OF PERJURY UNDER THE LAWS OF THE STATE OF CALIFORNIA THAT THE FOREGOING IS TRUE AND CORRECT.
Sig~D[_g Party, Printed Name. Title Date
(Revised 09 13 18)
I
CITY OF PALM SPRINGS -PUBLIC INTEGRITY DISCLOSURE
APPLICANT DISCLOSURE FORM
ATTACHMENT D
Item 1I - Page 16
CITY OF PALM SPRINGS – PUBLIC INTEGRITY DISCLOSURE
(INSTRUCTION FOR APPLICANTS)
(Revised 09 13 18)
CITY OF PALM SPRINGS
PUBLIC INTEGRITY DISCLOSURE
(INSTRUCTIONS FOR APPLICANTS)
Who Must File?
Applicants that are NOT a natural person or group of natural people that will be identified on the application, and seek a City approval determined by a vote of City officials . Examples include corporations, limited liability companies, trusts, etc. that seek a City Council approval, or an approval by one of the City’s board or commissions.
Why Must I File?
The City of Palm Springs Public Integrity Ordinance advances transparency in municipal government and assists public officials in avoiding conflicts of int erest. The City ’s Public Integrity Ordinance, codified in Chapter 2.60 of the municipal code, reflects the City’s interest in ensuring that companies (and other legal entities that are not natural people) doing business in the community are transparent and make disclosure as to their ownership and management, and further that those companies disclose the identity of any person , with an ownership interest worth two thousand dollars ($2,000) or more, who has a material financial relationship with any elected or appointed voting City official, or with the City Manager or City Attorney.
Note: A material financial relationship is a relationship between someone who is an owner/investor in the applic ant entity and a voting official (or the City Manager or City Attorney), which relationship includes any of the following:
(1) the owner/investor and the official have done business together during the year prior to the application;
(2) the official has earned income from the owner/investor during the year prior to the filing of the application;
(3) the owner/investor has given the official gifts worth fifty dollars ($50) or more during the year prior to the filing of the application; or
(4) the official might reasonably be anticipated to gain or lose money or a thing of value, based upon the owner/investor’s interest in the applicant entity, in relation to the application’s outcome.
When Must I File?
You must file this form with the Office of the City Clerk at the same time when you file your application for a City approval determined by a vote of City officials, whether elected or appointed.
Item 1I - Page 17
CITY OF PALM SPRINGS – PUBLIC INTEGRITY DISCLOSURE
(INSTRUCTION FOR APPLICANTS)
(Revised 09 13 18)
What Must I Disclose?
A. The names of all natural persons who are officers, directors, members, managers, trustees, and other fiduciaries serving trusts or other types of organizations (attorneys, accountants, etc.).
Note: (1) only trusts or other organizations that are not the fiduciaries, (2) if a second entity that is not a natural person serves the applicant entity (e.g., as a member of an applicant LLC), then all officers, directors, members, managers, trustees, etc., of the second entity must be disclosed).
B. The names of persons owning an interest with a value of two thousand dollars ($2,000) or more who have a material financial relationship with an elected or appointed City official who will vote on the applicant’s application, or with the City Manager or City Attorney.
PENALTIES
Falsification of information or failure to report information required to be reported may subject you to administrative action by the City.
Item 1I - Page 18
CITY OF PALM SPRINGS – PUBLIC INTEGRITY DISCLOSURE
APPLICANT DISCLOSURE FORM
(Revised 09 13 18)
PUBLIC INTEGRITY DISCLOSURE
APPLICANT DISCLOSURE FORM
1. Name of Entity
2. Address of Entity (Principle Place of Business)
3. Local or California Address (if different than #2)
4. State where Entity is Registered with Secretary of State If other than California, is the Entity also registered in California? Yes No
5. Type of Entity
Corporation Limited Liability Company Partnership Trust Other (please specify)
6. Officers, Directors, Members, Managers , Trustees, Other Fiduc iaries (please specify) Note: If any response is not a natural person, please identify all officers, directors, members, managers and other fiduciaries for the member, manager, trust or other entity _________________________________________________ Officer Director Member Manager [name]
General Partner Limited Partner
Other ____________________________________
_________________________________________________ Officer Director Member Manager [name]
General Partner Limited Partner
Other ____________________________________
_________________________________________________ Officer Director Member Manager [name]
General Partner Limited Partner
Other ____________________________________
150 PlayCore Drive SE, Fort Payne, AL 35967
N/A
Wisconsin
Roger Posacki
Richard E. Ruegger
PlayCore Wisconsin, Inc. dba GameTime
Item 1I - Page 19
-
..,,,
-
..,,,
..,,,
..,,,
-
I
CITY OF PALM SPRINGS – PUBLIC INTEGRITY DISCLOSURE
APPLICANT DISCLOSURE FORM
(Revised 09 13 18)
7. Owners/Investors with a 5% beneficial interest in the Applicant Entity or a related entity
EXAMPLE
JANE DOE
[name of owner/investor]
50%, ABC COMPANY, Inc.
[percentage of beneficial interest in entity
and name of entity]
A.
[name of owner/investor] [percentage of beneficial interest in entity
and name of entity]
B.
[name of owner/investor] [percentage of beneficial interest in entity
and name of entity]
C.
[name of owner/investor] [percentage of beneficial interest in entity
and name of entity]
D.
[name of owner/investor] [percentage of beneficial interest in entity
and name of entity]
E.
[name of owner/investor] [percentage of beneficial interest in entity and name of entity]
I DECLARE UNDER PENALTY OF PERJURY UNDER THE LAWS OF THE STATE OF CALIFORNIA THAT THE FOREGOING IS TRUE AND CORRECT.
Signature of Disclosing Party, Printed Name, Title Date Court Square Capital Partners
100% - Court Square Captital Partners
Stacey Grupenhagen
Contract Administrator
03/27/2025
Item 1I - Page 20
ATTACHMENT E
Item 1I - Page 21
55575.18165\33505817.1
Revised 10.5.21 1 SHORT FORM CONSTRUCTION CONTRACT
CITY OF PALM SPRINGS
SHORT FORM CONSTRUCTION CONTRACT 24I283
DESERT HIGHLAND PARK EXERCISE EQUIPMENT PURCHASE AND INSTALLATION
1. PARTIES AND DATE.
This Contract is made and entered into this 28th day of October 2024 by and between the City of Palm Springs, a California charter city and municipal corporation (“City”) and Playcore Wisconsin, Inc., DBA GameTime, a Wisconsin corporation with its principal place of business at 544 Chestnut Street, Chattanooga, TN 37402 (“Contractor”). City and Contractor are sometimes individually referred to as “Party” and collectively as “Parties” in this Contract.
2. RECITALS.
2.1 Cit y . City is a public agency organized under the laws of the State of California, with power to contract for services necessary to achieve its purpose.
2.2 Contractor. Contractor desires to perform and assume responsibility for the provision of certain construction services required by the City on the terms and conditions set forth in this Contract. Contractor represents that it is duly licensed and experienced in providing procurement and installation of exercise equipment at Desert Highland Park related construction services to public clients, that it and its employees or subcontractors have all necessary licenses and permits to perform the services in the State of California, and that it is familiar with the plans of City. The following license classifications are required for this Project: Class B
2.3 Project. Cit y desires to engage Contractor to render such services for the Desert Highland Park Exercise Equipment Purchase and Installation (“ Project”) as set forth in this Contract.
2.4 Project Documents & Certifications . Contractor has obtained, and delivers concurrently herewith, payment and performance bonds, and insurance documents as required by the Contract.
3. T ERMS
3.1 Compensation and Payment.
3.1.1 A mount of Compensation . As consideration for performance of the Work required herein, City agrees to pay Contractor the Total Contract Price of Sixty-Nine Thousand Thirty -Two Dollars and Thirty -Eight Cents ($69,032.38) (“Total Contract Price” ) provided that such amount shall be subject to adjustment pursuant to the applicable terms of this Contract or written change orders approved and signed in advance by the City.
3.1.2 Pay
ment of Compensation. If the Work is scheduled for completion in thirty (30) or less calendar days, City will arrange for payment of the Total Contract Price upon completion and approval by City of the Work. If the Work is scheduled for completion in more than thirty (30) calendar days, City will pay Contractor on a monthly basis as provided for herein.
On or before the fifth (5th) day of each month, Contractor shall submit to the City an itemized application for payment in the format supplied by the City indicating the amount of Work completed since commencement of the Work or since the last progress payment. These applications shall Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 22
55575.18165\33505817.1
Revised 10.5.21 2 SHORT FORM CONSTRUCTION CONTRACT
be supported by evidence which is required by this Contract and such other documentation as the City may require. The Contractor shall certify that the Work for which payment is requested has been done and that the materials listed are stored where indicated. Contractor may be required to furnish a detailed schedule of values upon request of the City and in such detail and form as the City shall request, showing the quantities, unit prices, overhead, profit, and all other expenses involved in order to provide a basis for determining the amount of progress payments.
3.1.3 P rompt Payment . City shall review and pay all progress payment requests in accordance with the provisions set forth in Section 20104.50 of the California Public Contract Code. However, no progress payments will be made for Work not completed in accordance with this Contract. Contractor shall comply with all applicable laws, rules and regulations relating to the proper payment of its employees, subcontractors, suppliers or others.
3.1.4 Cont ract Retentions . If this Contract is greater than Five Thousand dollars ($5,000), from each approved progress estimate, five percent (5%) will be deducted and retained by the City, and the remainder will be paid to Contractor. All Contract retention shall be released and paid to Contractor and subcontractors pursuant to California Public Contract Code Section 7107.
3.1.5 Ot
her Retentions . In addition to Contract retentions, the City may deduct from each progress payment an amount necessary to protect City from loss because of:
(1) liquidated damages which have accrued as of the date of the application for payment; (2) any sums expended by the City in performing any of Contractor’s obligations under the Contract which Contractor has failed to perform or has performed inadequately; (3) defective Work not remedied; (4) stop notices as allowed by state law; (5) reasonable doubt that the Work can be completed for the unpaid balance of the Total Contract Price or within the scheduled completion date; (6) unsatisfactory prosecution of the Work by Contractor; (7) unauthorized deviations from the Contract; (8) failure of Contractor to maintain or submit on a timely basis proper and sufficient documentation as required by the Contract or by City during the prosecution of the Work; (9) erroneous or false estimates by Contractor of the value of the Work performed; (10) any sums representing expenses, losses, or damages as determined by the City , incurred by the City for which Contractor is liable under the Contract; and (11) any other sums which the City is entitled to recover from Contractor under the terms of the Contract or pursuant to state law, including Section 1727 of the California Labor Code. The failure by the City to deduct any of these sums from a progress payment shall not constitute a waiver of the City’s right to such sums.
3.1.6 Sub
stitutions for Contract Retentions . Pursuant to California Public Contract Code section 22300, Contractor may substitute securities for any money withheld by the City to ensure the performance under the Contract. At the request and expense of Contractor, securities equivalent to the amount withheld shall be deposited with the City, with the State or a federally chartered bank as the escrow agent, who shall return such securities to Contractor upon satisfactory completion of the Contract. Deposit of securities with an escrow agent shall be subject to a written agreement between the escrow agent and the City, which provides that no portion of the securities shall be paid to Contractor until the City has certified to the escrow agent, in writing, that the Contract has been satisfactorily completed. The City shall certify that the Contract has been satisfactorily completed within sixty (60) days of work "completion" as defined in Section 7107(c) of the California Public Contract Code. Securities eligible for investment under this section shall be limited to those listed in Section 16430 of the Government Code, bank or savings & loan certificates of deposit, interest-bearing demand deposit accounts, stand-by letters of credit, or any other security mutually agreed to by Contractor.
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 23
55575.18165\33505817.1
Revised 10.5.21 3 SHORT FORM CONSTRUCTION CONTRACT
3.1.7 Payment to Subcontractors. Contractor shall pay all subcontractors for and on account of work performed by such subcontractors in accordance with the terms of their respective subcontracts and as provided for in Section 7108.5 of the California Business and Professions Code. Such payments to subcontractors shall be based on the measurements and estimates made and progress payments provided to Contractor pursuant to this Contract.
3.1.8 Tit
le to Work. As security for partial, progress, or other payments, title to Work for which such payments are made shall pass to the City at the time of payment. To the extent that title has not previously been vested in the City by reason of payments, full title shall pass to the City at delivery of the Work at the destination and time specified in this Contract. Such transferred title shall in each case be good, free and clear from any and all security interests, liens, or other encumbrances. Contractor promises and agrees that it will not pledge, hypothecate, or otherwise encumber the items in any manner that would result in any lien, security interest, charge, or claim upon or against said items. Such transfer of title shall not imply acceptance by the City, nor relieve Contractor from the responsibility to strictly comply with the Contract, and shall not relieve Contractor of responsibility for any loss of or damage to items.
3.1.9 Labor
and Material Releases. Contractor shall furnish City with labor and material releases from all subcontractors performing work on, or furnishing materials for, the Work governed by this Contract prior to final payment by City.
3.2 I
ncorporation of Documents. This Contract includes and hereby incorporates in full by reference the following documents, including all exhibits, drawings, specifications and documents therein, and attachments and addenda thereto:
• Services/Schedule (Exhibit “A”)
• Schedule of Compensation (Exhibit “B”)
• Special Conditions (Exhibit “C”)
• Contractor’s Certificate Regarding Workers’ Compensation (Exhibit “D”) • Public Works Contractor Registration Certification (Exhibit “E”) • Payment and Performance Bonds (Exhibit “F”)
• Executive Order N-6-22 Certification (Exhibit “G”)
• Change Orders executed by the City
To the extent there is a conflict between any portions of this Contract, the order of precedence shall be as follows: change orders, special conditions, technical specifications, plans/construction drawings, general contract terms, scope of work, standard plans, advertisements for bid/proposals, bids/proposals or other documents submitted by Contractor.
3.3 Contractor’s Basic Obligation; Scope of Work.
3.3.1 S
cope of Work. Contractor promises and agrees, at its own cost and expense, to furnish to the City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately complete the Project, including all structures and facilities necessary for the Project or described in the Contract (hereinafter sometim es referred to as the “ Work”), for a Total Contract Price as specified pursuant to this Contract. All Work shall be subject to, and performed in accordance with the above referenced documents, as well as the exhibits attached hereto and incorporated herein by reference. The plans and specifications for the Work are further described in Exhibit “B” attached hereto and incorporated herein by this reference. Special C onditions, if any, relating to the Work are described in Exhibit “C” attached hereto and incorporated herein by this reference.
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 24
55575.18165\33505817.1
Revised 10.5.21 4 SHORT FORM CONSTRUCTION CONTRACT
3.3.2 Change in Scope of Work. Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition or deletion i s approved in advance and in writing by a valid change order executed by the City.
3.3.3 Chan
ge Orders. Changes to the Contract Time (as defined in Section
3.3) or Total Contract Price shall be in the form of a written Change Order, either signed by both parties or issued unilaterally by the City. No adjustment shall be made to the Contract Time unless the delay impacts the critical path to completion and the delay was not caused in whole or in part by the Contractor. The City’s liability to Contractor for delays for which the City is responsible shall be limited to only an extension of time unless such delays were unreasonable under the circumstances. Failure to timely request a Change Order shall constitute a waiver of any right to adjust the Contract Time or the Total Contract Price. All requests for Change Orders shall be accompanied by detailed supporting documentation, including but not limited to payroll records, invoices, schedules, and any other documentation requested by the City for the purpose of determining the additional costs or the impact of any delay. If the change involves Work bid at a unit price, then the Total Contract Price shall be increased at the unit price. If there is no unit price, then the Total Contract Price shall be adjusted to account for costs actually incurred plus an allowed mark-up of fifteen percent (15%), which shall constitute the entire amount of profit, mark- ups, field or home office overhead costs, including personnel, equipment or office space, any materials, or any costs of equipment idle time for such work. Regardless of ownership, equipment rates shall not exceed the listed prevailing rates at local equipment rental agencies, or distributors, at the time the work is performed. Nothing herein shall prevent the Parties from agreeing to a lump sum cost.
3.3.4 Chan
ges Ordered By City. City may at any time issue a written directive ordering additions, deletions, or changes to the Work. Contractor shall proceed with the work in accordance with the directive. To the extent the directive results in extra work or requires additional Contract Time, Contractor shall request a Change Order within seven (7) days of receiving the Work Directive. If any costs are not capable of being determined within seven (7) days, then Contractor shall request a Change Order within seven (7) days of when the costs are capable of being determined.
3.3.5 Chan
ges Requested By Contractor. With respect to any matter that may involve or require an adjustment to the Contract Time or the Contract Price, Contractor shall provide written notice of the underlying facts and circumstances that gave rise to the potential change within seven (7) days or prior to the alteration of conditions, whichever is earlier. Failure to give notice shall constitute a waiver of Contractor’s right to a change order. If any costs are not capable of being determined within seven (7) days, then Contractor shall request a Change Order within seven (7) days of when the costs are capable of being determined.
3.4 S
ubstitutions/”Or Equal”. Pursuant to Public Contract Code Section 3400(b), the City may make a finding that designates certain products, things, or services by specific brand or trade name. Unless specifically designated in this Contract, whenever any material, process, or article is indicated or specified by grade, patent, or proprietary name or by name of manufacturer, such Specifications shall be deemed to be used for the purpose of facilitating the description of the material, process or article desired and shall be deemed to be followed by the words “or equal.”
Contractor may, unless otherwise stated, offer for substitution any material, process or Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 25
55575.18165\33505817.1
Revised 10.5.21 5 SHORT FORM CONSTRUCTION CONTRACT
article which shall be substantially equal or better in every respect to that so indicated or specified in this Contract. However, the City may have adopted certain uniform standards for certain materials, processes and articles. Contractor shall submit requests, together with substantiating data, for substitution of any “or equal” material, process or article no later than thirty-five (35) days after award of the Contract. To facilitate the construction schedule and sequencing, some requests may need to be submitted before thirty-five (35) days after award of Contract. Provisions regarding submission of “or equal” requests shall not in any way authorize an extension of time for performance of this Contract. If a proposed “ or equal ” substitution request is rejected, Contractor shall be responsible for providing the specified material, process or article. The burden of proof as to the equality of any material, process or article shall rest with Contractor.
The City has the complete and sole discretion to determine if a material, process or article is an “or equal” material, process or article that may be substituted. Data required to substantiate requests for substitutions of an “or equal” material, process or article data shall include a signed affidavit from Contractor stating that, and describing how, the substituted “or equal” material, process or article is equivalent to that specified in every way except as listed on the affidavit.
Substantiating data shall include any and all illustrations, specifications, and other relevant data including catalog information which describes the requested substituted “or equal” material, process or article, and substantiates that it is an “or equal” to the material, process or article. The substantiating data must also include information regarding the durability and lifecycle cost of the requested substituted “or equal” material, process or article. Failure to submit all the required substantiating data, including the signed affidavit, to the City in a timely fashion will result in the rejection of the proposed substitution.
Contractor shall bear all of the City’s costs associated with the review of substitution requests. Contractor shall be responsible for all costs related to a substituted “or equal” material, process or article. Contractor is directed to the Special Conditions (if any) to review any findings made pursuant to Public Contract Code section 3400.
3.5 Period of Performance and Liquidated Damages.
3.5.1 Contractor shall perform and complete all Work under this Contract within 50 working days, beginning the effective date of the Notice to Proceed ( “Contract Time”).
Contractor shall perform its Work in strict accordance with any completion schedule, construction schedule or project milestones developed by the City. Such schedules or milestones may be included as part of Exhibits “A” or “B” attached hereto, or may be provided separately in writing to Contractor. Contractor agrees that if such Work is not completed within the aforementioned Contract Time and/or pursuant to any such completion schedule, construction schedule or project milestones developed pursuant to provisions of the Contract, it is understood, acknowledged and agreed that the City will suffer damage. Pursuant to Government Code Section 53069.85, Contractor shall pay to the City as fixed and liquidated damages the sum of One Thousand Dollars ($1,000) per day for each and every calendar day of delay beyond the Contract Time or beyond any completion schedule, construction schedule or Project milestones established pursuant to the Contract.
3.5.2 If Contractor is delayed in the performance or progress of the Work by a Force Majeure Event (as defined herein), then the Contractor shall be entitled to a time extension, as provided herein, when the Work stopped is on the critical path and shall not be charged liquidated damages. Such a non- compensable adjustment shall be Contractor’s sole and exclusive remedy for such delays and the Contractor will not receive an adjustment to the Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 26
55575.18165\33505817.1
Revised 10.5.21 6 SHORT FORM CONSTRUCTION CONTRACT
Total Contract Price or any other compensation. Contractor must submit a timely request in accordance with the requirements of the Contract.
3.5.3 A Force Majeure Event shall mean an event that materially affects a party’s performance and is one or more of the following: (1) Acts of God or other natural disasters occurring at the project site; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the work); (4) pandemics, epidemics or quarantine restrictions; and (5) strikes and other organized labor action occurring at the project site and the effects thereof on the work, only to the extent such strikes and other organized labor action are beyond the control of Contractor and its subcontractors, of every tier, and to the extent the effects thereof cannot be avoided by use of replacement workers. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of the City in its capacity as a municipal authority.
3.6 Standard of Performance; Performance of Employees. Contractor shall perform all Work under this Contract in a skillful and workmanlike manner, and consistent with the standards generally recognized as being employed by professionals in the same discipline in the State of California. Contractor represents and maintains that it is skilled in the professional calling necessary to perform the Work. Contractor warrants that all employees and subcontractors shall have sufficient skill and experience to perform the Work assigned to them.
Finally, Contractor represents that it, its employees and subcontractors have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Work, including a City Business License, and that such licenses and approvals shall be maintained throughout the term of this Contract. As provided for in the indemnification provisions of this Contract, Contractor shall perform, at its own cost and expense and without reimbursement from the City, any work necessary to correct errors or omissions which are caused by Contractor ’s failure to comply with the standard of care provided for herein. Any employee who is determined by the City to be uncooperative, incompetent, a threat to the safety of persons or the Work, or any employee who fails or refuses to perform the Work in a manner acceptable to the City , shall be promptly removed from the Project by Contractor and shall not be re-employed on the Work.
3.7 Control and Payment of Subordinates; Contractual Relationship. City retains Contractor on an independent contractor basis and Contractor is not an employee of City . Any additional personnel performing the work governed by this Contract on behalf of Contractor shall at all times be under Contractor’s exclusive direction and control. Contractor shall pay all wages, salaries, and other amounts due such personnel in connection with their performance under this Contract and as required by law. Contractor shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, and workers’ compensation insurance.
3.8 City’s Basic Obligation. City agrees to engage and does hereby engage Contractor as an independent contractor to furnish all materials and to perform all Work according to the terms and conditions herein contained for the sum set forth above. Except as otherwise provided in the Contract, the City shall pay to Contractor, as full consideration for the satisfactory performance by Contractor of the services and obligations required by this Contract, the below - referenced compensation in accordance with compensation provisions set forth in the Contract.
3.9 Labor.
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 27
55575.18165\33505817.1
Revised 10.5.21 7 SHORT FORM CONSTRUCTION CONTRACT
3.9.1 Prevailing Wages. Contractor is aware of the requirements of California Labor Code Section 1720 et seq., and 1770 et seq., as well as California Code of Regulations, Title 8, Section 16000 et seq., (“Prevailing Wage Laws”), which require the payment of prevailing wage rates and the performance of other requirements on “ public works ” and “maintenance” projects. Since the Work is being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and if the total compensation is $15,000 or more for maintenance or $25,000 or more for construction, alteration, demolition, installation, or repair , Contractor agrees to fully comply with such Prevailing Wage Laws. City shall provide Contractor with a copy of the prevailing rates of per diem wages in effect at the commencement of this Contract. Contractor shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services available to interested parties upon request, and shall post copies at Contractor’s principal place of business and at the project site. Contractor shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws. Contractor and any subcontractor shall forfeit a penalty of up to $200 per calendar day or portion thereof for each worker paid less than the prevailing wage rates.
3.9.2 Appr
enticeable Crafts. When Contractor employs workmen in an apprenticeable craft or trade, Contractor shall comply with the provisions of Section 1777.5 of the California Labor Code with respect to the employment of properly registered apprentices upon public works. The primary responsibility for compliance with said section for all apprenticeable occupations shall be with Contractor. The Contractor or any subcontractor that is determined by the Labor Commissioner to have knowingly violated Section 1777.5 shall forfeit as a civil penalty an amount not exceeding $100 for each full calendar day of noncompliance, or such greater amount as provided by law.
3.9.3 Hour
s of Work . Contractor is advised that eight (8) hours labor constitutes a legal day’s work. Pursuant to Section 1813 of the California Labor Code, Contractor shall forfeit a penalty of $25.00 per worker for each day that each worker is permitted to work more than eight (8) hours in any one calendar day and forty (40) hours in any one calendar week, except when payment for overtime is made at not less than one and one- half (1-1/2) times the basic rate for that worker.
3.9.4 Pay roll Records. Contractor and each subcontractor shall keep an accurate payroll record, showing the name, address, social security number, work classification, straight time and overtime hours worked each day and week, and the actual per diem wages paid to each journeyman, apprentice, worker, or other employee employed by him or her in connection with the public work. The payroll records shall be certified and shall be available for inspection at all reasonable hours at the principal office of Contractor in the manner provided in Labor Code section 1776. In the event of noncompliance with the requirements of this section, Contractor shall have 10 days in which to comply subsequent to receipt of written notice specifying in what respects such Contractor must comply with this section. Should noncompliance still be evident after such 10-day period, Contractor shall, as a penalty to City, forfeit not more than $100.00 for each calendar day or portion thereof, for each worker, until strict compliance is effectuated. The amount of the forfeiture is to be determined by the Labor Commissioner. A contractor who is found to have violated the provisions of law regarding wages on Public Works with the intent to defraud shall be ineligible to bid on Public Works contracts for a period of one to three years as determined by the Labor Commissioner. Upon the request of the Division of Apprenticeship Standards or the Division of Labor Standards Enforcement, such penalties shall be withheld from progress payments then due. The responsibility for compliance with this section is on Contractor.
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 28
55575.18165\33505817.1
Revised 10.5.21 8 SHORT FORM CONSTRUCTION CONTRACT
In accordance with Labor Code section 1771.4, the Contractor and each subcontractor shall furnish the certified payroll records directly to the Department of Industrial Relations (“DIR”) on a weekly basis and in the format prescribed by the DIR, which may include electronic submission.
The requirement to submit certified payroll records directly to the Labor Commissioner under Labor Code section 1771.4 shall not apply to work performed on a public works project that is exempt pursuant to the small project exemption specified in Labor Code Section 1771.4.
3.9.5 C
ontractor and Subcontractor Registration. Pursuant to Labor Code sections 1725.5 and 1771.1, all contractors and subcontractors that wish to bid on, be listed in a bid proposal, or enter into a contract to perform public work must be registered with the DIR. No bid will be accepted nor any contract entered into without proof of the contractor ’s and subcontractors’ current registration with the DIR to perform public work. Contractor is directed to review, fill out and execute the Public Works Contractor Registration Certification attached hereto as Exhibit “E” prior to contract execution. Notwithstanding the foregoing, the contractor registration requirements mandated by Labor Code Sections 1725.5 and 1771.1 shall not apply to work performed on a public works project that is exempt pursuant to the small project exemption specified in Labor Code Sections 1725.5 and 1771.1.
3.9.6 Labor
Compliance; Stop Orders. This Project is subject to compliance monitoring and enforcement by the DIR. It shall be the Contractor’s sole responsibility to evaluate and pay the cost of complying with all labor compliance requirements under this Contract and applicable law. Any stop orders issued by the DIR against Contractor or any subcontractor that affect Contractor’s performance of Work, including any delay, shall be Contractor’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Contractor caused delay subject to any applicable liquidated damages and shall not be compensable by the City. Contractor shall defend, inde mnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the DIR against Contractor or any subcontractor.
3.10 P
erformance of Work; Jobsite Obligations.
3.10.1 W ater Quality Management and Compliance.
3.10.1.1 Water Quality Management and Compliance. Contractor shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Work including, without limitation, all applicable provisions of the Federal Water Pollution Control Act (33 U.S.C. §§ 1300); the California Porter -Cologne Water Quality Control Act (Cal Water Code §§ 13000- 14950); local ordinances regulating discharges of storm water; and any and all regulations, policies, or permits issued pursuant to any such authority regulating the discharge of pollutants, as that term is used in the Porter -Cologne Water Quality Control Act, to any ground or surface water in the State.
3.10.1.2 Com
pliance with the Statewide Construction General Permit .
Contractor shall comply with all conditions of the most recent iteration of the National Pollutant Discharge Elimination System General Permit for Storm Water Discharges Associated with Construction Activity, issued by the California State Water Resources Control Board (“Permit”). It shall be Contractor’s sole responsibility to file a Notice of Intent and procure coverage under the Permit for all construction activity which results in the disturbance of more than one acre of total land area or which is part of a larger common area of development or sale. Prior to initiating work, Contractor shall be solely responsible for preparing and implementing a Storm Water Pollution Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 29
55575.18165\33505817.1
Revised 10.5.21 9 SHORT FORM CONSTRUCTION CONTRACT
Prevention Plan (SWPPP) as required by the Permit. Contractor shall be responsible for procuring, implementing and complying with the provisions of the Permit and the SWPPP, including the standard provisions, and monitoring and reporting requirements as required by the Permit. The Permit requires the SWPPP to be a “living document” that changes as necessary to meet the conditions and requirements of the job site as it progresses through difference phases of construction and is subject to different weather conditions. It shall be Contractor ’s sole responsibility to update the SWPPP as necessary to address conditions at the project site.
3.10.1.3 O
ther Water Quality Rules Regulations and Policies. Contractor shall comply with the lawful requirements of any applicable municipality, drainage City , or local agency regarding discharges of storm water to separate storm drain systems or other watercourses under their jurisdiction, including applicable requirements in municipal storm water management programs.
3.10.1.4 Cos
t of Compliance. Storm, surface, nuisance, or other waters may be encountered at various times during construction of the Work. Therefore, the Contractor, hereby acknowledges that it has investigated the risk arising from such waters and assumes any and all risks and liabilities arising therefrom.
3.10.1.5 Liabi
lity for Non- Compliance. Failure to comply with laws,
regulations, standards, ordinances, and permits listed in Sections 3. 10.1.1, 3.10.1.2, 3.10.1.3, and 3.10.1.4 of the Contract is a violation of federal and state law. Pursuant to the indemnification provisions of this Contract, Contractor hereby agrees to defend, indemnify and hold harmless the City and its directors, officials, officers, employees, volunteers and agents for any alleged violations. In addition, City may seek damages from Contractor for any delay in completing the Work in accordance with the Contract, if such delay is caused by or related to Contractor’s failure to comply with the Permit.
3.10.1.6 Res
ervation of Right to Defend. City reserves the right to defend any enforcement action brought against the City for Contractor’s failure to comply with the Permit or any other relevant water quality law, regulation, or policy. Pursuant to the indemnification provisions of this Contract, Contractor hereby agrees to be bound by, and to reimburse the City for the costs (including the City’s attorney ’s fees) associated with, any settlement reached between the City and the relevant enforcement entity.
3.10.1.7 Tr
aining. In addition to the standard of performance
requirements set forth in this Contract, Contractor warrants that all employees and subcontractors shall have sufficient skill and experience to perform the work assigned to them without impacting water quality in violation of the laws, regulations and pol icies described in paragraph 3.10. 1.
Contractor further warrants that it, its employees and subcontractors will receive adequate training, as determined by City, regarding the requirements of the laws, regulations and pol icies described in paragraph 3.10.1 as they may relate to the Work provided under this Contract. Upon request, City will provide the Contractor with a list of training programs that meet the requirements of this paragraph.
3.10.2 Saf ety. Contractor shall execute and maintain its work so as to avoid injury or damage to any person or property. Contractor shall comply with the requirements of the specifications relating to safety measures applicable in particular operations or kinds of work. In carrying out its Work, Contractor shall at all times be in compliance with all applicable local, state and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of employees appropriate to the nature of the Work and the conditions under which the Work is Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 30
55575.18165\33505817.1
Revised 10.5.21 10 SHORT FORM CONSTRUCTION CONTRACT
to be performed. Safety precautions as applicable shall include, but shall not be limited to, adequate life protection and lifesaving equipment; adequate illumination for underground and night operations; instructions in accident prevention for all employees, such as machinery guards, safe walkways, scaffolds, ladders, bridges, gang planks, confined space procedures, trenching and shoring, fall protection and other safety devices, equipment and wearing apparel as are necessary or lawfully required to prevent accidents or injuries; and adequate facilities for the proper inspection and maintenance of all safety measures. Furthermore, Contractor shall prominently display the names and telephone numbers of at least two medical doctors practicing in the vicinit y of the Project, as well as the telephone number of the local ambulance service, adjacent to all telephones at the Project site.
3.10.3 Law
s and Regulations. Contractor shall keep itself fully informed of and in compliance with all local, state and federal laws, rules and regulations in any manner affecting the performance of the Contract or the Work, including all Cal/OSHA requirements, and shall give all notices required by law. Contractor shall be liable for all violations of such laws and regulations in connection with the Work. If Contractor observes that the drawings or specifications are at variance with any law, rule or regulation, it shall promptly notify the City in writing. Any necessary changes shall be made by written change order. If Contractor performs any work knowing it to be contrary to such laws, rules and regulations and without giving written notice to the City , Contractor shall be solely responsible for all costs arising therefrom. City is a public entity of the State of California subject to certain provisions of the Health & Safety Code, Government Code, Public Contract Code, and Labor Code of the State. It is stipulated and agreed that all provisions of the law applicable to the public contracts of a municipality are a part of this Contract to the same extent as though set forth herein and will be complied with. Contractor shall defend, indemnify and hold City, its officials, directors, officers, employees and agents free and harmless, pursuant to the indemnification provisions of this Contract, from any claim or liability arising out of any failure or alleged failure to comply with such laws, rules or regulations.
3.10.4 Per
mits and Licenses. Contractor shall be responsible for securing City permits and licenses necessary to perform the Work described herein, including, but not limited to, a City Business License. While Contractor will not be charged a fee for any City permits, Contractor shall pay the City’s applicable business license fee. Any ineligible contractor or subcontractor pursuant to Labor Code Sections 1777.1 and 1777.7 may not perform work on this Project.
3.10.5 Tr enching Work. If the Total Contract Price exceeds $25,000 and if the Work governed by this Contract entails excavation of any trench or trenches five (5) feet or more in depth, Contractor shall comply with all applicable provisions of the California Labor Code, including Section 6705. To this end, Contractor shall submit for City’s review and approval a detailed plan showing the design of shoring, bracing, sloping, or other provisions to be made for worker protection from the hazard of caving ground dur ing the excavation of such trench or trenches. If such plan varies from the shoring system standards, the plan shall be prepared by a registered civil or structural engineer.
3.10.6 Haz
ardous Materials and Differing Conditions. As required by California Public Contract Code Section 7104, if this Contract involves digging trenches or other excavations that extend deeper than four (4) feet below the surface, Contractor shall promptly, and prior to disturbance of any conditions, n otify City of: (1) any material discovered in excavation that Contractor believes to be a hazardous waste that is required to be removed to a Class I, Class II or Class III disposal site; (2) subsurface or latent physical conditions at the site differing from those indicated by City ; and (3) unknown physical conditions of an unusual nature at the site, Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 31
55575.18165\33505817.1
Revised 10.5.21 11 SHORT FORM CONSTRUCTION CONTRACT
significantly different from those ordinarily encountered in such contract work. Upon notification, City shall promptly investigate the conditions to determine whether a change order is appropriate.
In the event of a dispute, Contractor shall not be excused from any scheduled completion date and shall proceed with all Work to be performed under the Contract, but shall retain all rights provided by the Contract or by law for making protests and resolving the dispute.
3.10.7 U
nderground Utility Facilities. To the extent required by Section 4215 of the California Government Code, City shall compensate Contractor for the costs of: (1) locating and repairing damage to underground utility facilities not caused by the failure of Contractor to exercise reasonable care; (2) removing or relocating underground utility facilities not indicated in the construction drawings; and (3) equipment necessarily idled during such work. Contractor shall not be assessed liquidated damages for delay caused by failure of City to provide for removal or relocation of such utility facilities.
3.10.8 Air Quality. Contractor must fully comply with all applicable laws, rules and regulations in furnishing or using equipment and/or providing services, including, but not limited to, emissions limits and permitting requirements imposed by the California Air Resources Board (CARB). Although CARB limits and requirements are more broad, Contractor shall specifically be aware of their application to “ portable equipment”, which definition is considered by CARB to include any item of equipment with a fuel-powered engine. Contractor shall indemnify City against any fines or penalties imposed by CARB, or any other governmental or regulatory agency for violations of applicable laws, rules and/or regulations by Contractor, its subcontractors, or others for whom Contractor is responsible under its indemnity obligations provided for in this Contract.
3.10.9 St
ate Recycling Mandates . Contractor shall comply with State Recycling Mandates. Any recyclable materials/debris collected by the contractor that can be feasibly diverted via reuse or recycling must be hauled by the appropriate handler for reuse or recycling.
3.10.10 Ins
pection Of Site . Contractor has visited sites where Work is to be performed and has become acquainted with all conditions affecting the Work. Contractor warrants that it has made such examinations as it deems necessary to determine the condition of the Work sites, its a ccessibility to materials, workmen and equipment, and to determine the Contractor’s ability to protect existing surface and subsurface improvements. No claim for allowances–time or money–will be allowed as to such matters.
3.10.11 Fi eld Measurements. Contractor shall make field measurements, verify field conditions and shall carefully compare such field measurements and conditions and other information known to Contractor with the Contract Documents before commencing activities.
Errors, inconsistencies or omissions discovered shall be reported to the City immediately and prior to performing any work or altering the condition.
3.11 C
ompletion of Work. When Contractor determines that it has completed the Work required herein, Contractor shall so notify City in writing and shall furnish all labor and material releases required by this Contract. City shall thereupon inspect the Work. If the Work is not acceptable to the City , the City shall indicate to Contractor in writing the specific portions or items of Work which are unsatisfactory or incomplete. Once Contractor determines that it has completed the incomplete or unsatisfactory Work, Contractor may request a re-inspection by the City. Once the Work is acceptable to City , City shall pay to Contractor the Total Contract Price remaining to be paid, less any amount which City may be authorized or directed by law to retain.
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 32
55575.18165\33505817.1
Revised 10.5.21 12 SHORT FORM CONSTRUCTION CONTRACT
Payment of retention proceeds due to Contractor shall be made in accordance with Section 7107 of the California Public Contract Code.
3.12 Claims; Government Code Claim Compliance.
3.12.1 I ntent. Effective January 1, 1991, Section 20104 et seq., of the California Public Contract Code prescribes a process utilizing informal conferences, non-binding judicial supervised mediation, and judicial arbitration to resolve disputes on construction claims of $375,000 or less. Effective January 1, 2017, Section 9204 of the Public Contract Code prescribes a process for negotiation and mediation to resolve disputes on construction claims.
The intent of this Section is to implement Sections 20104 et seq. and Secti on 9204 of the California Public Contract Code. This Section shall be construed to be consistent with said statutes.
3.12.2 Claim
s. For purposes of this Section, “Claim” means a separate demand by the Contractor, after a change order duly requested in accordance with the terms of this Contract has been denied by the City, for (A) a time extension, (B) payment of money or damages arising from Work done by or on behalf of the Contractor pursuant to the Contract, or (C) an amount the payment of which is disputed by the City. A “Claim” does not include any demand for payment for which the Contractor has failed to provide notice, request a change order, or otherwise failed to follow any procedures contained in the Contract Documents.
3.12.3 Filin
g Claims. Claims governed by this Section may not be filed unless and until the Contractor completes all procedures for giving notice of delay or change and for the requesting of a time extension or change order, including but not necessarily limited to the change order procedures contained herein, and Contractor’s request for a change has been denied in whole or in part. Claims governed by this Section must be filed no later than fourteen (14) days after a request for change has been denied in whole or in part or after any other event giving rise to the Claim. The Claim shall be submitted in writing to the City and shall include on its first page the following in 16 point capital font: “THIS IS A CLAIM.” Furthermore, the claim shall include the documents necessary to substantiate the claim. Nothing in this Section is intended to extend the time limit or supersede notice requirements otherwise provided by contract for the filing of claims, including all requirements pertaining to compensation or payment for extra Work, disputed Work, and/or changed conditions. Failure to follow such contractual requirements shall bar any claims or subsequent lawsuits for compensation or payment thereon.
3.12.4 Su
pporting Documentation. The Contractor shall submit all claims in the following format:
3.12.4.1 S ummary of claim merit and price, reference Contract Document provisions pursuant to which the claim is made
3.12.4.2 List of documents relating to claim:
(A) Specifications
(B) Drawings
(C) Clarifications (Requests for Information)
(D) Schedules
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 33
55575.18165\33505817.1
Revised 10.5.21 13 SHORT FORM CONSTRUCTION CONTRACT
(E) Other
3.12.4.3 Chronology of events and correspondence
3.12.4.4 Analysis of claim merit
3.12.4.5 Analysis of claim cost , including calculations and supporting documents
3.12.4.6 Time impact analysis in CPM format
3.12.5 Cit y’s Response. Upon receipt of a Claim pursuant to this Section, City shall conduct a reasonable review of the Claim and, within a period not to exceed 45 days of receipt of the Claim, or as extended by mutual agreement, shall provide the Contractor a written statement identifying what portion of the C laim is disputed and what portion is undisputed. Any payment due on an undisputed portion of the C laim will be processed and made within 60 days after the City issues its written statement.
3.12.5.1 If Cit y needs approval from its governing body to provide the Contractor a written statement identifying the disputed portion and the undisputed portion of the Claim, and the governing body does not meet within the 45 days or within the mutually agreed to extension of time following receipt of a Claim sent by registered mail or certified mail, return receipt requested, City shall have up to three (3) days following the next duly publicly noticed meeting of the governing body after the 45 -day period, or extension, expires to provide the Contractor a written statement identifying the disputed portion and the undisputed portion.
3.12.5.2 Within 30 days of receipt of a Claim, City may request in writing additional documentation supporting the C laim or relating to defenses or claims City may have against the Contractor. If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement of City and the Contractor. City’s written response to the Claim, shall be submitted to the Contractor within 30 Days (if the Claim is less than $50,000, within 15 Days) after receipt of the additional documentation, or within a period of time no greater than that taken by the Contractor in producing the additional information or requested documentation, whichever is greater.
3.12.6 M
eet and Confer. If the Contractor disputes City’s written response, or City fails to respond within the time prescribed, the Contractor may so notify City, in writing, within 15 Days of receipt of City’s response or the City’s failure to respond, and demand an informal conference to meet and confer for settlement of the issues in dispute. Upon receipt of a demand, City shall schedule a meet and confer conference within 30 Days for settlement of the dispute.
3.12.7 Medi
ation. Within 10 business days following the conclusion of the meet and confer conference, if the Claim or any portion of the Claim remains in dispute, City shall provide the Contractor a written statement identifying the portion of the Claim that remains in dispute and the portion that is undisputed. Any payment due on an undisputed portion of the Claim shall be processed and made within 60 Days after City issues its written statement. Any disputed portion of the Claim, as identified by the Contractor in writing, shall be submitted to nonbinding mediation, with City and the Contractor sharing the associated costs equally. City and Contractor shall mutually agree to a mediator within 10 business days after the disputed portion of the Claim has been identified in writing, unless the Parties agree to select a mediator at a later time.
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 34
55575.18165\33505817.1
Revised 10.5.21 14 SHORT FORM CONSTRUCTION CONTRACT
3.12.7.1 If the Parties cannot agree upon a mediator, each P arty shall select a mediator and those mediators shall select a qualified neutral third party to mediate with regard to the disputed portion of the claim. Each Party shall bear the fees and costs charged by its respective mediator in connection with the selection of the neutral mediator.
3.12.7.2 For purposes of this section, mediation includes any nonbinding process, including, but not limited to, neutral evaluation or a dispute review board, in which an independent third party or board assists the P arties in dispute resolution through negotiation or by issuance of an evaluation. Any mediation utilized shall conform to the timeframes in this section.
3.12.7.3 Unless otherwise agreed to by City and the Contractor in writing, the mediation conducted pursuant to this section shall excuse any further obligation under Section 20104.4 to mediate after litigation has been commenced.
3.12.7.4 The mediation shall be held no earlier than the date the Contractor completes the Work or the date that the Contractor last performs Work, whichever is earlier. All unresolved Claims shall be considered jointly in a single mediation, unless a new unrelated Claim arises after mediation is completed.
3.12.8 P
rocedures After Mediation. If following the mediation, the Claim or any portion remains in dispute, the Contractor must file a claim pursuant to Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code. For purposes of those provisions, the running of the period of time within which a claim must be filed shall be tolled from the time the Contractor submits his or her written Claim pursuant to subdivision (a) until the time the Claim is denied, including any period of time utilized by the meet and confer conference or mediation.
3.12.9 Civil A
ctions. The following procedures are established for all civil actions filed to resolve Claims of $375,000 or less:
3.12.9.1 W ithin 60 Days, but no earlier than 30 Days, following the filing or responsive pleadings, the court shall submit the matter to non-binding mediation unless waived by mutual stipulation of both Parties or unless mediation was held prior to commencement of the action in accordance with Public Contract Code section 9204 and the terms of these procedures.
The mediation process shall provide for the selection within 15 D ays by both Parties of a disinterested third person as mediator, shall be commenced within 30 Days of the submittal, and shall be concluded within 15 Days from the commencement of the mediation unless a time requirement is extended upon a good cause showing to the court.
3.12.9.2 If the matter remains in dispute, the case shall be submitted to judicial arbitration pursuant to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, notwithstanding Section 1114.11 of that code. The Civil Discovery Act of 1986 (Article 3 (commencing with Section 2016) of Chapter 3 of Title 3 of Part 4 of the Code of Civil Procedure) shall apply to any proceeding brought under this subdivision consistent with the rules pertaining to judicial arbitration.
3.12.9.3 In addition to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, (A) arbitrators shall, when possible, be experienced in construction law, and (B) any party appealing an arbitration award who does not Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 35
55575.18165\33505817.1
Revised 10.5.21 15 SHORT FORM CONSTRUCTION CONTRACT
obtain a more favorable judgment shall, in addition to payment of costs and fees under that chapter, also pay the attorney’s fees on appeal of the other party.
3.12.10 G overnment Code Claim Procedures.
3.12.10.1 This section does not apply to tort claims and nothing in this section is intended nor shall be construed to change the time periods for filing tort claims or actions specified by Chapter 1 (commending with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.5 of Title 1 of the Government Code.
3.12.10.2 In addition to any and all Contract requirements pertaining to notices of and requests for adjustments to the Contract Time, Contract Price, or compensation or payment for extra work, disputed work, claims and/or changed conditions, Contractor must comply with the claim procedures set forth in Government Code sections 900 et seq. prior to filing any lawsuit against the City.
3.12.10.3 Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to adjustment of the Contract Time, Contract Price, or compensation or payment for extra work, disputed work, claims, and/or changed conditions have been followed by Contractor. If no such Government Code claim is submitted, or if any prerequisite contractual requirements are not otherwise satisfied as specified herein, Contrac tor may not file any action against the City.
3.12.10.4 A Government Code claim must be filed no earlier than the date the work is completed or the date the Contractor last performs work on the Project, whichever occurs first. A Government Code claim shall be inclusive of all unresolved Claims known to the Contractor excepting only new unrelated C laims that arise after the Government Code claim is submitted.
3.12.11 No
n-Waiver. City’s failure to respond to a Claim from the Contractor within the time periods described in this section or to otherwise meet the time requirements of this section shall result in the C laim being deemed rejected in its entirety and shall not constitute a waiver of any rights under this section.
3.13 L oss and Damage. Except as may otherwise be limited by law, Contractor shall be responsible for all loss and damage which may arise out of the nature of the Work agreed to herein, or from the action of the elements, or from any unforeseen difficulties which may arise or be encountered in the prosecution of the Work until the same is fully completed and accepted by City. In the event of damage proximately caused by an Act of God, as defined by Section 7105 of the Public Contract Code, the City may terminate this C ontract pursuant to the termination provisions in this Contract; provided, however, that the City needs to provide Contractor with only one (1) day advanced written notice.
3.14 Indemnification.
3.14.1 S
cope of Indemnity. To the fullest extent permitted by law, Contractor shall defend, indemnify and hold the City, its officials, employees, agents free and harmless from any and all claims, demands, causes of action, suits, actions, proceedings, costs, expenses, liability, judgments, awards, decrees, settlements, loss, damage or injury of any kind, in law or equity, regardless of whether the allegati ons are false, fraudulent, or groundless, to property or Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 36
55575.18165\33505817.1
Revised 10.5.21 16 SHORT FORM CONSTRUCTION CONTRACT
persons, including wrongful death, (collectively, “Claims”) in any manner arising out of, pertaining to, or incident to any negligent acts, errors or omissions, or willful misconduct of Contractor, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Contractor’s services, the Project or this Contract, including without limitation the payment of all expert witness fees, attorneys’ fees and other related costs and expenses.
Notwithstanding the foregoing, to the extent required by Civil Code section 2782, Contractor’s indemnity obligation shall not apply to such loss or damage which is caused by the sole or active negligence or willful misconduct of the City.
3.14.2 A
dditional Indemnity Obligations. Contractor shall defend, with counsel reasonably acceptable to City and at Contractor’s own cost, expense and risk, any and all Claims covered by this section that may be brought or instituted against City or its officials, employees, agents. In addition, Contractor shall pay and satisfy any judgment, award or decree that may be rendered against City or its officials, employees, agents as part of any such claim, suit, action or other proceeding Contractor shall also reimburse City for the cost of any settlement paid by City or its officials, employees, agents as part of any such claim, suit, action or other proceeding. Such reimbursement shall include payment for City’s attorney’s fees and costs, including expert witness fees. Contractor shall reimburse City and its officials, employees, agents, for any and all legal expenses and costs incurred by each of them in connection therewith or in enforcing the indemnity herein provided. Contractor’s obligation to indemnify shall survive expiration or termination of this Contract, and shall not be restricted to insurance proceeds, if any, received by the City, its officials, employees, agents.
3.15 I
nsurance.
3.15.1 T ime for Compliance. Contractor shall not commence Work under this Contract until it has provided evidence satisfactory to the City that it has secured all insurance required under this section. In addition, Contractor shall not allow any subcontractor to commence work on any subcontract until it has provided evidence satisfactory to the City that the subcontractor has secured all insurance required under this section. Failure to provide and maintain all required insurance shall be grounds for the City to terminate this Contract for cause.
3.15.2 Mi
nimum Requirements. Contractor shall, at its expense, procure and maintain for the duration of the Contract insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the Work hereunder by Contractor, its agents, representatives, employees or subcontractors. Contractor shall also require all of its subcontractors to procure and maintain the same insurance for the duration of the Contract. Such insurance shall meet at least the f ollowing minimum levels of coverage:
3.15.2.1 Mi
nimum Scope of Insurance. Coverage shall be at least as broad as the latest version of the following: (1) General Liability: Insurance Services Office Commercial General Liability coverage (occurrence form CG 00 01) (coverage for operations of designated contractor); (2) Automobile Liability Auto Form CAN 103809MT, code 1 (any auto); (3) Workers’ Compensation and Employer ’s Liability: Workers’ Compensation insurance as required by the State of California and Employer’s Liability Insurance; and (4) Builders’/All Risk:
Builders’/All Risk via property insurance covering for all risks of loss, including explosion, collapse, underground excavation and removal of lateral support (and including earthquakes and floods if requested by the City). Policies shall not contain exclusions contrary to this Contract.
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 37
55575.18165\33505817.1
Revised 10.5.21 17 SHORT FORM CONSTRUCTION CONTRACT
3.15.2.2 Minimum Limits of Insurance. Contractor shall maintain limits no less than: (1) General Liability: $2,000,000 per occurrence and $4,000,000 general aggregate for bodily injury, personal injury and property damage; (2) Automobile Liability: $1,000,000 per accident for bodily injury and property damage; (3) Workers ’ Compensation and Employer ’s Liability: Workers’ compensation limits as required by the Labor Code of the State of California.
Employer’s Liability limits of $1,000,000 each accident, policy limit bodily injury or disease, and each employee bodily injury or disease; and (4) Builders’/All Risk via property insurance :
Completed value of the project. Defense costs shall be available in addition to the limits.
Notwithstanding the minimum limits specified herein, any available coverage shall be provided to the parties required to be named as additional insureds pursuant to this Contract.
3.15.2.3 Not ices; Cancellation or Reduction of Coverage . At least ten (10 days following to the expiration of any such policy, evidence showing that such insurance coverage has been renewed or extended shall be filed with the City. If such coverage is cancelled or materially reduced, Contractor shall, within ten (10) days after receipt of written notice of such cancellation or reduction of coverage, file with the City evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies. In the event any policy of insurance required under this Contract does not comply with these specifications or is canceled and not replaced, the City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by the City will be promptly reimbursed by Contractor or the City may withhold amounts sufficient to pay premium from Contractor payments. In the alternative, the City may suspend or terminate this Contract.
3.15.3 Ins
urance Endorsements . The insurance policies shall contain the following provisions, or Contractor shall provide endorsements (amendments) on forms or approved by the City to add the following provisions to the insurance policies:
3.15.3.1 Gen
eral Liability. (1) Such policy shall give the City, its officials, employees, agents additional insured status using ISO endorsements CG20 10 04/13 plus CG20 37 04/13 , or endorsements providing the exact same coverage, with respect to the Work or operations performed by or on behalf of Contractor, including materials, parts or equipment furnished in connection with such work; (2) all policies shall waive or shall permit Contractor to waive all rights of subrogation which may be obtained by the Contractor or any insurer by virtue of payment of any loss or any coverage provided to any person named as an additional insured pursuant to this Contract, and Contractor agrees to waive all such rights of subrogation; and (3) the insurance coverage shall be primary insurance as respects the City, its officials, employees, agents, or if excess, shall stand in an unbroken chain of coverage excess of Contractor ’s scheduled underlying coverage. Any insurance or self -insurance maintained by the City, its officials, employees, agents and volunteers shall be excess of Contractor ’s insurance and shall not be called upon to contribute with it.
3.15.3.2 Au
tomobile Liability . (1) Such policy shall give the City, its officials, employees, agents additional insured status with respect to the ownership, operation, maintenance, use, loading or unloading of any auto owned, leased, hired or borrowed by Contractor or for which Contractor is responsible; (2) all policies shall waive or shall permit Contractor to waive all rights of subrogation which may be obtained by the Contractor or any insurer by virtue of payment of any loss or any coverage provided to any person named as an additional insured pursuant to this Contract, and Contractor agrees to waive all such rights of subrogation; and (3) the insurance coverage shall be primary insurance as respects the City, its officials, employees, agents, or if excess, shall stand in an unbroken chain of coverage excess of Contractor’s scheduled underlying coverage. Any insurance or self-insurance maintained by the Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 38
55575.18165\33505817.1
Revised 10.5.21 18 SHORT FORM CONSTRUCTION CONTRACT
City, its officials, employees, agents and volunteers shall be excess of Contractor’s insurance and shall not be called upon to contribute with it in any way.
3.15.3.3 W orkers’ Compensation and Employer ’s Liability Coverage.
The insurer shall agree to waive all rights of subrogation against the City, its officials, employees, agents for losses paid under the terms of the insurance policy which arise from work performed by Contractor.
3.15.3.4 Al l Coverages. Each insurance policy required by this Contract shall be endorsed to state that: (1) coverage shall not be suspended, voided, reduced or canceled except after thirty (30) days prior written notice by certified mail, return receipt requested, has been given to the City ; and (2) any failure to comply with reporting or other provisions of the policies, including breaches of warranties, shall not affect coverage provided to the City, its officials, employees, agents.
3.15.4 Bu ilders’/All Risk Policy Requirements. The builders’/all risk insurance shall provide that the City be named as loss payee via property coverage. In addition, the insurer shall waive all rights of subrogation against the City.
3.15.5 Sep aration of Insureds; No Special Limitations. All insurance required by this Section shall contain standard separation of insureds provisions. In addition, such insurance shall not contain any special limitations on the scope of protection afforded to the City, its officials, employees, agents.
3.15.6 Pr
ofessional Liability Insurance. All architects, engineers, consultants or design professionals retained by Contractor shall also procure and maintain, for a period of five (5) years following completion of the Contract, errors and omissions liability insurance with a limit of not less than $1,000,000 per occurrence. This insurance shall name the City, its directors, officials, officers, employees, agents and volunteers as additional and insureds with respect to Work performed, and shall otherwise comply with all requirements of this Section. Defense costs shall be paid in addition to the limits.
3.15.7 Dedu
ctibles and Self -Insurance Retentions. Any deductibles or self - insured retentions must be declared to and approved by the City. GameTime has an SIR of $250,000 which cannot be waived or reduced. GameTime shall be solely responsible for any such self-insured retention amount.
3.15.8 Ac ceptability of Insurers. Insurance is to be placed with insurers with a current A.M. Best’s rating no less than A:VII, licensed to do business in California, and satisfactory to the City. Exception may be made for the State Compensation Insurance Fund when not specifically rated.
3.15.9 Ver ification of Coverage. Contractor shall furnish City with original certificates of insurance and endorsements effecting coverage required by this Contract on forms satisfactory to the City . The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf, and shall be on forms supplied or approved by the City. All certificates and endorsements must be received and approved by the City before work commences. The City reserves the right to require complete, certified copies of all required insurance policies, at any time.
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 39
55575.18165\33505817.1
Revised 10.5.21 19 SHORT FORM CONSTRUCTION CONTRACT
3.15.10 Subcontractors. All subcontractors shall meet the requirements of this Section before commencing Work. Contractor shall furnish separate certificates and endorsements for each subcontractor. Subcontractor policies of General Liability insurance shall name the City, its officials, employees, agents as additional insureds using form ISO 20 38 04 13 or endorsements providing the exact same coverage. All coverages for subcontractors shall be subject to all of the requirements stated herein except as otherwise agreed to by the City in writing.
3.15.11 Repor
ting of Claims. Contractor shall report to the City , in addition to Contractor’s insurer, any and all insurance claims submitted by Contractor in connection with the Work under this Contract.
3 .16 Bond Requirements.
3.16.1 P ayment Bond. If required by law or otherwise specifically requested by City in Exhibit “C” attached hereto and incorporated herein by reference, Contractor shall execute and provide to City concurrently with this Contract a Payment Bond in an amount required by the City and in a form provided or approved by the City. If such bond is required, no payment will be made to Contractor until the bond has been received and approved by the City.
3.16.2 Per formance Bond. If specifically requested by City in Exhibit “C” attached hereto and incorporated herein by reference, Contractor shall execute and provide to City concurrently with this Contract a Performance Bond in an amount required by the City and in a form provided or approved by the City. If such bond is required, no payment will be made to Contractor until the bond has been received and approved by the City.
3.16.3 Bon d Provisions . Should, in City’s sole opinion, any bond become insufficient or any surety be found to be unsatisfactory, Contractor shall renew or replace the effected bond within (ten) 10 days of receiving notice from City . In the event the surety or Contractor intends to reduce or cancel any required bond, at least thirty (30) days prior written notice shall be given to the City, and Contractor shall post acceptable replacement bonds at least ten (10) days prior to expiration of the original bonds. No further payments shall be deemed due or will be made under this Contract until any replacement bonds required by this Section are accepted by the City. To the extent, if any, that the Total Contract Price is increased in accordance with the Contract, Contractor shall, upon request of the City, cause the amount of the bond to be increased accordingly and shall promptly deliver satisfactory evidence of such increase to the City. If Contractor fails to furnish any required bond, the City may terminate the C ontract for cause.
3.16.4 Sur
ety Qualifications. Only bonds executed by an admitted surety insurer, as defined in California Code of Civil Procedure Section 995.120, shall be accepted. If a California-admitted surety insurer issuing bonds does not meet these requirements, the insurer will be considered qualified if it is in conformance with Section 995.660 of the California Code of Civil Procedure, and proof of such is provided to the City.
3.17 W arranty. Contractor warrants all Work under the Contract (which for purposes of this Section shall be deemed to include unauthorized work which has not been removed and any non-conforming materials incorporated into the Work) to be of good quality and free from any defective or faulty material and workmanship. Contractor agrees that for a period of one year (or the period of time specified elsewhere in the Contract or in any guarantee or warranty provided Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 40
55575.18165\33505817.1
Revised 10.5.21 20 SHORT FORM CONSTRUCTION CONTRACT
by any manufacturer or supplier of equipment or materials incorporated into the Work, whichever is later) after the date of final acceptance, Contractor shall within ten (10) days after being notified in writing by the City of any defect in the Work or non- conformance of the Work to the Contract, commence and prosecute with due diligence all Work necessary to fulfill the terms of the warranty at its sole cost and expense. Contractor shall act sooner as requested by the City in response to an emergency. In addition, Contractor shall, at its sole cost and expense, repair and replace any portions of the Work (or work of other contractors) damaged by its defective Work or which becomes damaged in the course of repairing or replacing defective Work. For any Work so corrected, Contractor’s obligation hereunder to correct defective Work shall be reinstated for an additional one year period, commencing with the date of acceptance of such corrected Work.
Contractor shall perform such tests as the City may require to verify that any corrective actions, including, without limitation, redesign, repairs, and replacements comply with the requirements of the Contract. All costs associated with such corrective actions and testing, including the removal, replacement, and reinstitution of equipment and materials necessary to gain access, shall be the sole responsibility of Contractor. All warranties and guarantees of subcontractors, suppliers and manufacturers with respect to any portion of the Work, whether express or implied, are deemed to be obtained by Contractor for the benefit of the City, regardless of whether or not such warranties and guarantees have been transferred or assigned to the City by separate agreement and Contractor agrees to enforce such warranties and guarantees, if necessary, on behalf of the City. In the event that Contractor fails to perform its obligations under this Section, or under any other warranty or guaranty under this Contract, to the reasonable satisfaction of the City, the City shall have the right to correct and replace any defective or non- conforming Work and any work damaged by such work or the replacement or correction thereof at Contractor ’s sole expense.
Contractor shall be obligated to fully reimburse the City for any expenses incurred hereunder upon demand.
3.18 Employee/Labor Certifications.
3.18.1 C
ontractor’s Labor Certification. By its signature hereunder, Contractor certifies that he is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker’s Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Work. A certification form for this purpose, which is attached to this Contrac t as Exhibit “D” and incorporated herein by reference, shall be executed simultaneously with this Contract.
3.18.2 Equ al Opportunity Employment. Contractor represents that it is an equal opportunity employer and that it shall not discriminate against any employee or applicant for employment because of race, religion, color, national origin, ancestry, sex, age or other interests protected by the State or Federal Constitutions. Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination.
3.18.3 Ver
ification of Employment Eligibility . By executing this Contract, Contractor verifies that it fully complies with all requirements and restrictions of state and federal law respecting the employment of undocumented aliens, including, but not limited to, the Immigration Reform and Control Ac t of 1986, as may be amended from time to time, and shall require all subcontractors and sub-subcontractors to comply with the same.
3.19 Te
rmination. This Contract may be terminated by City at any time, either with our without cause, by giving Contractor three (3) days advance written notice. In the event of Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 41
55575.18165\33505817.1
Revised 10.5.21 21 SHORT FORM CONSTRUCTION CONTRACT
termination by City for any reason other than the fault of Contractor, City shall pay Contractor for all Work performed up to that time as provided herein. In the event of breach of the Contract by Contractor, City may terminate the Contract immediately without notice, may reduce payment to Contractor in the amount necessary to offset City’s resulting damages, and may pursue any other available recourse against Contractor. Contractor may not terminate this Contract except for cause. In the event this Contract is terminated in whole or in part as provided, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated. Further, if this Contract is terminated as provided, City may require Contractor to provide all finished or unfinished documents, data, diagrams, drawings, materials or other matter prepared or built by Contractor in connection with its performance of this Contract. Contractor shall be required to provide such document and other information within fifteen (15) days of the request. In the event of termination of this Contract for convenience, Subcontractor shall be paid the applicable contract value for all compliant completed increments of Work and Work in progress.
3.20 City Officers and Employees: Non-Discrimination.
3.20.1 No
n-liability of City Officers and Employees. No officer or employee of the City shall be personally liable to the Contractor, or any successor -in-interest, in the event of any default or breach by the City or for any amount which may become due to the Contractor or to its successor, or for breach of any obligation of the terms of this Contract.
3.20.2 Conf
lict of Interest . Contractor acknowledges that no officer or employee of the City has or shall have any direct or indirect financial interest in this Contract nor shall Contractor enter into any agreement of any kind with any such officer or employee during the term of this Contract and for one (1) year thereafter. Contractor warrants that Contractor has not paid or given, and will not pay or give, any third party any money or other consideration in exchange for obtaining this Contract.
3.20.3 Cov
enant Against Discrimination. In connection with its performance under this Contract , Contractor shall not discriminate against any employee or applicant for employment because of actual or perceived race, religion, color, sex, age, marital status, ancestry, national origin ( i.e., place of origin, immigration status, cultural or linguistic characteristics, or ethnicity), sexual orientation, gender identity, gender expression, physical or mental disability, or medical condition (each a “prohibited basis”). Contractor shall ensure that applicants are employed, and that employees are treated during their employment, without regard to any prohibited basis. As a condition precedent to City’s lawful capacity to enter this Contract , and in executing this Contract, Contractor certifies that its actions and omissions hereunder shall not incorporate any discrimination arising from or related to any prohibited basis in any Contractor activity, including but not limited to the following: employment, upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship; and further, that Contractor is in full compliance with the provisions of Palm Springs Municipal Code Section 7.09.040, including without limitation the provision of benefits, relating to non-discrimination in city contracting.
3.21 G
eneral Provisions.
3.21.1 Cit y’s Representative. The City hereby designates the City Manager, or his or her designee, to act as its representative for the performance of this Contract ( “City’s Representative”). City’s Representative shall have the power to act on behalf of the City for all Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 42
55575.18165\33505817.1
Revised 10.5.21 22 SHORT FORM CONSTRUCTION CONTRACT
purposes under this Contract. Contractor shall not accept direction or orders from any person other than the City’s Representative or his or her designee.
3.21.2 C ontractor’s Representative. Before starting the Work, Contractor shall submit in writing the name, qualifications and experience of its proposed representative who shall be subject to the review and approval of the City (“′Contractor’s Representative” ). Following approval by the City, Contractor’s Representative shall have full authority to represent and act on behalf of Contractor for all purposes under this Contract. Contractor ’s Representative shall supervise and direct the Work, using his best skill and attention, and shall be responsible for all construction means, methods, techniques, sequences and procedures and for the satisfactory coordination of all portions of the Work u nder this Contract. Contractor ’s Representative shall devote full time to the Project and either he or his designee, who shall be acceptable to the City, shall be present at the Work site at all times that any Work is in progress and at any time that any employee or subcontractor of Contractor is present at the Work site. Arrangements for responsible supervision, acceptable to the City , shall be made for emergency Work which may be required. Should Contractor desire to change its Contractor’s Representative, Contractor shall provide the information specified above and obtain the City’s written approval.
3.21.3 Cont
ract Interpretation. Should any question arise regarding the meaning or import of any of the provisions of this Contract or written or oral instructions from City, the matter shall be referred to City’s Representative, whose decision shall be binding upon Contractor.
3.21.4 An
ti-Trust Claims. This provision shall be operative if this Contract is applicable to California Public Contract Code Section 7103.5. In entering into this Contract to supply goods, services or materials, Contractor hereby offers and agrees to assign to the City all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Section 15) or under the Cartwright Act (Chapter 2, commencing with Section 16700, of Part 2 of Division 7 of the Business and Professions Code) arising from purchases of goods, services, or materials pursuant to the Contract. This assignment shall be made and become effective at the time the City tender final payment to Contractor, without further acknowledgment by the Parties.
3.21.5 Not
ices. All notices hereunder and communications regarding interpretation of the terms of the Contract or changes thereto shall be provided by the mailing thereof by registered or certified mail, return receipt requested, postage prepaid and addressed as follows:
CONTRACTOR:
PLAYCORE WISCONSIN, INC., DBA GAMETIME
544 CHESTNUT STREET CHATTANOOGA, TN 37402
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 43
55575.18165\33505817.1
Revised 10.5.21 23 SHORT FORM CONSTRUCTION CONTRACT
CITY:
CITY OF PALM SPRINGS
3200 E. TAHQUITZ CANYON WAY
PALM SPRINGS, CA 92262
ATTN: CITY MANAGER & CITY CLERK
Any notice so given shall be considered received by the other Party three (3) days after deposit in the U.S. Mail as stated above and addressed to the Party at the above address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.
3.21.6 T
ime of Essence. Time is of the essence in the performance of this Contract.
3.21.7 As signment Forbidden. Contractor shall not, either voluntarily or by action of law, assign or transfer this Contract or any obligation, right, title or interest assumed by Contractor herein without the prior written consent of City. If Contractor attempts an assignment or transfer of this Contract or any obligation, right, title or interest herein, City may, at its option, terminate and revoke the Contract and shall thereupon be relieved from any and all obligations to Contractor or its assignee or transferee.
3.21.8 No T
hird Party Beneficiaries. There are no intended third party beneficiaries of any right or obligation assumed by the Parties.
3.21.9 Laws ; Venue. This Contract shall be interpreted in accordance with the laws of the State of California. If any action is brought to interpret or enforce any term of this Contract, the action shall be brought in a state or federal court situated in the County of Riverside, State of California.
3.21.10 At torneys’ Fees. If either Party commences an action against the other party, either legal, administrative or otherwise, arising out of or in connection with this Contract , the prevailing party in such litigation shall be entitled to have and recover from the losing party reasonable attorneys’ fees and all other costs of such action.
3.21.11 Coun terparts. This Contract may be executed in counterparts, each of which shall constitute an original.
3.21.12 S u ccessors. The Parties do for themselves, their heirs, executors, administrators, successors, and assigns agree to the full performance of all of the provisions contained in this Contract.
3.21.13 So
licitation. Contractor maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Contractor, to solicit or secure this Contract. Further, Contractor warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Contractor, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Contract. For breach or violation of this warranty, City shall have the right to terminate this Contract without liability.
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 44
55575.18165\33505817.1
Revised 10.5.21 24 SHORT FORM CONSTRUCTION CONTRACT
3.21.14 Certification of License.
3.21.14.1 Contractor certifies that as of the date of execution of this Contract, Contractor has a current contractor’s license of the classification indicated below under Contractor’s signature.
3.21.14.2 Contractors are required by law to be licensed and regulated by the Contractors ’ State License Board which has jurisdiction to investigate complaints against contractors if a complaint regarding a patent act or omission is filed within four (4) years of the date of the alleged violation. A complaint regarding a latent act or omission pertaining to structural defects must be filed within ten (10) years of the date of the alleged violation. Any questions concerning a contractor may be referred to the Registrar, Contractors’ State License Board, P.O.
Box 26000, Sacramento, California 95826.
3.21.15 A
uthority to Enter Contract . Each Party warrants that the individuals who have signed this Contract have the legal power, right and authority to make this Contract and bind each respective Party.
3.21.16 En tire Contract; Modification . This Contract contains the entire agreement of the Parties with respect to the subject matter hereof, and supersedes all prior negotiations, understandings or agreements. This Contract may only be modified by a writing signed by both Parties.
3.21.17 Non-W
aiver. None of the provisions of this Contract shall be considered waived by either party, unless such waiver is specifically specified in writing.
3.21.18 City ’s Right to Employ Other Contractors. City reserves right to employ other contractors in connection with this Project or other projects.
3.22 C ompliance with Economic Sanctions in Response to Russia's Actions in Ukraine. When funding for the services is provided, in whole or in part, by an agency controlled of the State of California, Consultant shall fully and adequately comply with California Executive Order N-6-22 (“Russian Sanctions Program”). As part of this compliance process, Consultant shall also certify compliance with the Russian Sanctions Program by completing the form located in Attachment “G” (Russian Sanctions Certification), attached hereto and incorporated herein by reference. Consultant shall also require any subconsultants to comply with the Russian Sanctions Program and certify compliance pursuant to this Section. [Signatures on Next Page]
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 45
55575.18165\33505817.1
Revised 10.5.21 25 SHORT FORM CONSTRUCTION CONTRACT
SIGNATURE PAGE TO AGREEMENT BY AND BETWEEN THE CITY OF PALM SPRINGS AND PLAYCORE WISCONSIN, INC., DBA GAMETIME
IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below.
CONTRACTOR:
By: _____________________________________ By: _________________________________________ Signature Signature
(2nd signature required for Corporations)
Date: Date:
CITY OF PALM SPRINGS:
APPROVED BY CITY COUNCIL:
Date: _N/A______ Item No. N/A
APPROVED AS TO FORM: ATTEST:
By: ___________________________ By______________________________ City Attorney City Clerk
APPROVED:
By: _______________________________
Date:
Lauri Aylaian, Interim Parks & Recreation Director
By: _____________ __________________ Date:
City Manager – over $50,000
Deputy/Assistant City Manager – up to $50,000
Director – up to $25,000
Manager – up to $5,000
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 11/4/2024 11/6/2024
11/6/2024
11/7/2024
Item 1I - Page 46
~ DocuSigned by:
L~ft:t~~~
55575.18165\33505817.1
Revised 10.5.21 Exhibit A - 1 SHORT FORM CONSTRUCTION CONTRACT
EXHIBIT “A”
SERVICES / SCHEDULE
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 47
Proposa I for
City of Palm Springs
Prepared by
~
a > -
~ft EAT we.sreRN
02-20- 20 24
Job # 111199-01
Desert H ighlands Park Fitness Equipment Option 4A
( Ganie7ime)
805 4 320 ·9007 I www.gwpark.com
55575.18165\33505817.1
Revised 10.5.21 Exhibit A - 2 SHORT FORM CONSTRUCTION CONTRACT
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 48
55575.18165\33505817.1
Revised 10.5.21 Exhibit A - 3 SHORT FORM CONSTRUCTION CONTRACT
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 49
55575.18165\33505817.1
Revised 10.5.21 Exhibit A - 4 SHORT FORM CONSTRUCTION CONTRACT
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 50
55575.18165\33505817.1
Revised 10.5.21 Exhibit A - 5 SHORT FORM CONSTRUCTION CONTRACT
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 51
55575.18165\33505817.1
Revised 10.5.21 Exhibit A - 6 SHORT FORM CONSTRUCTION CONTRACT
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 52
Desert Highlands Park Fitness Equipment Option 4 - Project 111199-01-Opt 4 Palm Springs, CA
A STRONG ,ouNDATION IN l'\.AY POft OVl:ft 50 YURS rt (435) 245-50 55 I 1'1 435 245-15057 Myleea«'gwp:irtl.com 55575.18165\33505817.1
Revised 10.5.21 Exhibit A - 7 SHORT FORM CONSTRUCTION CONTRACT
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 53
~
IN- CROllND
( ADVANCED SERIES)
13561:
0 USAGE/WARNING
LABEL SIGN POST
13565
A
G ll l!.A T w_iesrER N
STEP- UP
F!TNES.S STA n oN
13569
I//
'M
LEC PRES$
(1"11~~~~1ND)
I
CAPTA;"IS CH AIR -
!N CROt.JNJ)
(~DW~s~iof ER!ES)
CH C:ST PRESS -
IN- Gf"<OUND
(ADVAfisi ~5r '-Rl[S)
f22s.4::_,:tz&izWLiW.2:3
CHIN- UP HIGH; t ow COMBO
IN·-GROUND
( AD\/ A~ 1~i5T ERi ES)
";;, ;<I
r}}f - ~ i ' Pl YOWETRiC
BOX STAilON
(ADVANCED SERIES)
1327€
r;///.·i')
rff_;;:
2· PL 'rOt1Ei R1C
BOX STA.llON
{AOVAN1~} ~a5ERIES)
i ·t2 ' -,22 ' ·r22- ·r?J-,U ' ·e:22 1
0 8 ..;LANCF. BEA\,1
ST','TION i3581
5'
10·
,s·
20'
55575.18165\33505817.1
Revised 10.5.21 Exhibit A - 8 SHORT FORM CONSTRUCTION CONTRACT
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 54
( Game7ime)
Game lime C/0 Great Westem Recrea:io n
P.O. Box 680 12 1
Fort Payn e . Al 35967
Office: 435-245-5055 F.l.X: 435-245-5057
www.gwpark .com
09/24/2024
Ouo:e#
111199-0 1-05
Desert Highlands Park Fitness Equipme nt Option 4A
City of Palm Springs
Ar-en: Jarvis Crawford
480 W Tramview Rd
Palm Springs. CA 92262
United States
Phone: 760-323-.927
[email protected] .gov
Ship to Zip 92262
Qty Part# Description List$ Selfing $ Ext. SeHmg $
13280 Game-Time - Balance Bo:lrd Sca:ion
135551 Game-Time- Chest Press {Single) - ln-Ground Mount 135591 Game-Time- Leg Press (Single)
135601 Game-Time - Capta in's Chair - In-Ground Mount
135611 Game Time - Sit Up/ Badi Extension
13569 Game-Time - SteJ>l/p Fitness Sta:ion
1358 1 Game-Time - Balance Beam Station
135851 Game-Time - Chin Up Hi lo C.Ombo In Ground
135891 Game-Time- Push Up H'tllo In ground
13276 Game-Time - PtyofT!Nic Box (12")
13278 GameTime- Ptyo~c Box (24•)
13585 Game-Time - Fimess Sign Post For Sticker
INSTALL Jn.s-1.lll - lnsta llation of Fi".ness Equipmem - Jns-1.lllation of qty (11} pieces of GT Fi".ness equipment.
P~ailing Wages
INSTALL Jn.SUII - Coordinate deTrvery of equipment and unload at project site.- P~ail ing w.:.ge.
Page I of4
S77 t.00 $632.22 S632.22
S5.884.00 $4.236.48 S4.236.48
56. 194.00 $4,459.68 S4.459.68
54,9 18.00 $3.540.96 S3.540.96
56. 164.00 $4,438.08 S4.438 .08
S2. t12.00 $ 1.520.64 Sl .520.64
S712.00 $512.64 S512.64
S3.339.00 $2,404.08 S2.404 .08
S2,58t.00 $ 1.858.32 Sl .858.32
S817.00 $588.24 S588.24
5914.00 $658.08 S658.08
S308.00 $22 1.76 S22 1.76
S35.097.04 S35.097.04 $35.097.04
S2.000.00 $2.000.00 S2.000 .00
Sub Total $62. 168.22
Freight S3.505.08
Tax S2.3 l 9.08
GREAT W EST E R N
i; R ~ A O ""
MMei.Ha,tvey
"" ... ,,.,.rt..w,.
55575.18165\33505817.1
Revised 10.5.21 Exhibit A - 9 SHORT FORM CONSTRUCTION CONTRACT
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 55
( Game7ime)
Game Time CIO Great Westem Recrea'!ion
P.O. Box 680 12 1
Fort Payn e . Al 35967
Office: 435-24>5055 Fax: 435-24>5057
www.gwpark.com
Desert Highlands Park Fitness Equipment Option 4A
Comments
09/24/2024
Ouo:e #
11t199-0 1-05
Your Sales Rep is Myles Harvey. Please reach out t o Myles at 805-320-9007 if you should have any questions regard ing this quote .
Due to the volatility of freight costs , the freight pricing is subject to change at lhe time of order.
Pricing is subject to ct.ange. Request updated pricing when purct.asing from quotes more than 30 days old.
To include a Payment and Perionnance Bond, please add $1,040.00 Shipping to site:
480WTramview Rd.
Palm Springs. CA 92262
'Freight charge s are based on lis::ed zip code and are subject to change if shipping information changes. ' Deposit mJ:'f be required.
Prevailing wage
Remit Payment to:
GameTime
P.O. Box 680 12 1
Fort Payne . AL 35968
Taxes:
All applicable taxes will be added a: time of invoicing unless otherwise included or a tax~ oertifica:e is provided.
If sales tax exem pt you must pro'\lide a oopy of certificate ::o be considered exem pt Prices :
FOB F actoty.
Orders:
All orders shall be in writing by purcha se order, contract. or similar document mlde out to Pla.yCote Wisoonsi n Inc.. dba Game Tune.
Standard Game Time equipment orders ow.r $ 100,000 may require a deposit of 25% a; the time of order and an additiona l 25% a; or be..-ore order ships Standard orders with equipment. installation and surfacing M e requested to be split billed.
Equipment , Taxes & Freigh, as noted above
Installation and Surfacing billed as completed and Cue Upon Receipt.
Terms :
Clsh With Orde.r Discount {ONO): Orders for Ga.me-Time equipment paid in full a, time of order via check. Elearon ic Funds Transfer (ACH or wire) are eligible for a .hree pe.rcem (3%) cash with order cftSCOUnt.
Payment via credit card: If you elect to pay by cred it card, GameTi:me cha rges a 2.50% processing fee that is assessed on the a mount of your payme nt. This fee is shown as a sepa rate l[ne item a nd included in the tot.al amount charged to your credit carcl. You have the option to pay by check. ACH or Wire without a ny additional fees.
Cred it te.nns are Net 30 days. s ubject :io approva l by the Ga.me-Time Cred i\ Manager. A completed credit applic..i.1ion m..rst be submitted and approved prior to ::he order being received . Please allow a: minirn..am 2 days for the crecfrt review process. Game Time may also reqU:re:
Comple-:ed Project lnform ation Sheet (if appficable)
Copies of P a.yment and Perforrna.noe Bonds (if appliClbJe) A t.5% pe.rmonth fina.noe charg e wiJ be imposed on al) past due invoices .
Rewinag e not aooepted .
Orde.rs unde.r $5.000 require payment with order.
GREAT W EST E R N
~ R f A O ""
Mlylea Hervey
~ ,,.,."-'-
55575.18165\33505817.1
Revised 10.5.21 Exhibit A - 10 SHORT FORM CONSTRUCTION CONTRACT
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 56
( Game7ime)
Game Time C/0 Great West.em Recrea:ion
P.O. Box 680 12 1
Fort Payn e . Al 35967
Office: 435-245-5055 Fax: 435-245-5057
www.gwpark .com
09/24/2024
Ouo:e#
11t1Q9-01-05
Desert Highlands Park Fitness Equipment Option 4A
INSTALLATION CONOmO NS:
ACCESS : Site should be clear, level and allow for unrestricted access of trucks and machinery.
STORAG E: Custome r is responsible for providing a secure locaticn to off-load and store the equipment during the insU!lation proce ss. Once equipment hai delive red to the site. the owner is responsibJe shoold theft or vandalism ooc:ur unless ooier arrangemerns are made and no:ed on the quotation.
FOOTER EXCAVATION: lnsullation pricing is based on foo:er exeavation through earth/-soil onty. Customer shall be responsi.ble for unknown cond itions sueh as buried utilJties {public & priva:e). tree stumps, rock, or :my concealed materials or conditions that m;,;y result in additional labor or materials cost.
UTILm ES: ONner is responsible for loc.1.iil"IQ any private util:iti:es.
ADDITIONA L COSTS: Pricing is based on a single mobilization fc< installation unless othetW se noted. Price includes ONLY what is stated in this quota tion If adcfrtional site w::rl or specia lized equipment is required, pricing is subject to c hange.
GREAT W EST E R N
~ R I' A O ""
~ lea Hervey
""°'''·-·~
55575.18165\33505817.1
Revised 10.5.21 Exhibit B - 1 SHORT FORM CONSTRUCTION CONTRACT
EXHIBIT “B”
SERVICES / SCHEDULE
Scope of services shall include the purchase and installation of 11 pieces of exercise equipment at Desert Highland Park as identified in Exhibit B.
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 57
55575.18165\33505817.1
Revised 10.5.21 Exhibit C - 1 SHORT FORM CONSTRUCTION CONTRACT
EXHIBIT “C”
SPECIAL CONDITIONS
ARTICLE 1. BONDS
Concurrently with this Contract, the Contractor shall deliver to the City four identical counterparts of the Performance Bond and Payment Bond on the forms supplied by the City and included as Exhibit “F” to the Contract. The surety supplying the bond must be an admitted surety insurer, as defined in Code of Civil Procedure Section 995.120, authorized to do business as such in the State of California and satisfactory to the City. The Performance Bond and the Payment Bond shall be for one hundred percent (100%) of the Total Contract Price.
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 58
55575.18165\33505817.1
Revised 10.5.21 Exhibit D - 1 SHORT FORM CONSTRUCTION CONTRACT
EXHIBIT “D”
CERTIFICATION
LABOR CODE - SECTION 1861
I, the undersigned Contractor, am aware of the provisions of Section 3700, et se q., of the California Labor Code which require every employer to be insured against liability for Worker ’s Compensation or to undertake self-insurance in accordance with the provisions of the Code, and I, the undersigned Contractor, agree to and will comply with such provisions before commencing the performance of the Work on this Contract.
PLAYCORE WISCONSIN, INC., DBA GAMETIME
By: _________________________
Signature
_________________________
Name (Print)
_________________________
Title (Print)
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Director of Sales Administration
Clint Whiteside
Item 1I - Page 59
55575.18165\33505817.1
Revised 10.5.21 Exhibit E - 1 SHORT FORM CONSTRUCTION CONTRACT
EXHIBIT “E”
PUBLIC WORKS CONTRACTOR REGISTRATION CERTIFICATION
Pursuant to Labor Code sections 1725.5 and 1771.1, all contractors and subcontractors that wish t
o bid on, be listed in a bid proposal, or enter into a contract to perform public work must be registered with the Department of Industrial Relations. See http://www.dir.ca.gov/Public- Works/PublicWorks.html for additional information.
No bid will be accepted nor any contract entered into without proof of the contractor ’s and subcontractors’ current registration with the Department of Industrial Relations to perform public work.
Contractor hereby certifies that it is aware of the registration requirements set forth in Labor Code sections 1725.5 and 1771.1 and is currently registered as a contractor with the Department of Industrial Relations.
1 Name of C ontractor :
DIR Registration Number:
DIR Registration Expiration: __________________________ Small Project Exemption: _____ Yes or _____ No
Unless Contractor is exempt pursuant to the small project exemption, Contractor further acknowledges:
1. Contractor shall maintain a current DIR registration for the duration of the project.
2. Contractor shall include the requirements of Labor Code sections 1725.5 and 1771.1 in its contract with subcontractors and ensure that all subcontractors are registered at the time of bid opening and maintain registration status for the duration of the project.
3. Failure to submit this form or comply with any of the above requirements may result in a finding that the bid is non-responsive.
Name of Contractor:____________________
Signature:
Name and Title:
Dated:
1 If the Project is exempt from the contractor registration requirements pursuant to the small project exemption under Labor Code Sections 1725.5 and 1771.1, please mark “Yes” in response to “Small Project Exemption.” Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 6/30/2025
PlayCore Wisconsin, Inc., DBA GameTime
1000015526
X
Director of Sales AdministrationClint Whiteside
11/4/2024
PlayCore Wisconsin, Inc., DBA GameTime
Item 1I - Page 60
55575.18165\33505817.1
Revised 4.13.23 Exhibit F - 1 SHORT FORM CONSTRUCTION CONTRACT
EXHIBIT “F”
PAYMENT AND PERFORMANCE BONDS
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 61
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 62
PAYMENT BOND
KNOW ALL MEN BY THESE PRESENTS That
Bond No. 0264629
WHEREAS, the City of Palm Springs (hereinafter designated as the "City"), by action taken or a resolution passed October 14, 2024 has awarded to Playcore Wisconsin, Inc., dba Game Time hereinafter designated as the "Principal," a contract for the work described as follows :
Desert Highland Park Exercise Equipment Purchase and Installation (the "Project"); and WHEREAS, the work to be performed by the Principal is more particularly set forth in the Contract Documents for the Project dated October 14, 2024 ("Contract Documents"), the terms and conditions of which are expressly incorporated by reference; and WHEREAS, said Principal is required to furnish a bond in connection with said contract; providing that if said Principal or any of its Subcontractors shall fail to pay for any materials , provisions, provender, equipment, or other supplies used in, upon, for or about the performance of the work contracted to be done, or for any work or labor done thereon of any kind, or for amounts due under the Unemployment Insurance Code or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of said Principal and its Subcontractors with respect to such work or labor the Surety on this bond will pay for the same to the extent hereinafter set forth.
NOW THEREFORE , we, the Principal and Berkley Insurance Company as Surety, are held and firmly bound unto the City in the penal sum of Sixty-Nine Thousand Thirty-Two Dollars and Thirty-Eight Cents ($69,032.38) lawful money of the United States of America , for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors , administrators, successors and assigns, jointly and severally, firmly by these presents.
THE CONDITION OF THIS OBLIGATION IS SUCH that if said Principal, his or its subcontractors , heirs, executors, administrators, successors or assigns, shall fail to pay any of the persons named in Section 9100 of the Civil Code, fail to pay for any materials, provisions or other supplies, used in, upon, for or about the performance of the work contracted to be done, or for any work or labor thereon of any kind, or amounts due under the Unemployment Insurance Code with respect to work or labor performed under the contract, or for any amounts required to be deducted, withheld , and paid over to the Employment Development Department or Franchise Tax Board from the wages of employees of the contractor and his subcontractors pursuant to Section 18663 of the Revenue and Taxation Code, with respect to such work and labor the Surety or Sureties will pay for the same, in an amount not exceeding the sum herein above specified, and also, in case suit is brought upon this bond, all litigation expenses incurred by City in such suit, including reasonable attorneys' fees, court costs, expert witness fees and investigation expenses.
This bond shall inure to the benefit of any of the persons named in Section 9100 of the Civil Code so as to give a right of action to such persons or their assigns in any suit brought upon this bond.
It is further stipulated and agreed that the Surety on this bond shall not be exonerated or released from the obligation of this bond by any change, extension of time for performance , addition, alteration or modification in, to, or of any contract, plans, specifications , or agreement pertaining or relating to any scheme or work of improvement herein above described, or pertaining Revised 4.13 .23
55575 .18 165\33505 8 17. 1
Exhibit F - 6 SHORT FORM ~ONSTRLJ.CTION~ONTRACT
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 63
Notary Acknowledgment
A notary public or other officer completing this
certificate verifies only the identity of the individual who signed the document to which this certificate is
attached, and not the truthfulness, accuracy, or validity of that document.
~~
STATE OF-G..A I IEQEM'JIA
COUNTY OF~~ ';"\11 L I '"':"\,..,, '
On ()C-"'"IQ b~ '? Q , 20.Z.--1, before me, ,,L&DQfCttll....V'J, V'' ~ personally
, Notary Public,
, who proved to me on the basis of satisfactory
evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. ,.._..,.,,,.,'&., .. _..... "Iii
I certify under PENAL TY 0 1;....P.ij~J~.~~ r• the laws of the State of California that the foregoing paragraph is true and correct. :'cf.,•• • •• "",,tSl••£
{ / ~OTAflJ, \ ~~ ~:,:. ! -·- i j W~ITNESS mJ.y handG)an~d o~cia l seal. ~i- \ "u ,c : "''-
Signature of No\~l''Jb lic BL / ~J
·~~··· .~ ~,# "' 4 ••••oe.-••g '\ 'v.,,:'
'\,!._TATE t--• OPTIONAL "'' '=''-'-'"
Though the inform ation below is not req uired by law, it may prove valuable to persons relying on the document
and could prevent fraudulent removal and reattachment of this form to another document.
CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT n Individual
~ Corporate Officer
~"'1' t jt..-'"12-l$4t--
Title(s)
n Partner(s) "J Limited
11 General
Attorney-In-Fact
Trustee(s)
Guardian/Conservator
Other:
Signer is representing:
Name Of Person(s) Or Entity(ies)
Revised 4_._Ll.23
55575. 18 165\335 058 17. I
Title or Type of Document
f)
Number of Pages
10 {2--°1 /L4--
Date of Document
Signer(s) Other Than Named Above
l;xhib it F - 8 SHORT FORM CONSTRUCTLOl',J CONTRACT
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 64
CALIFORNIA ALL- PURPOSE
CERTIFICATE OF ACKNOWLEDGMENT
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.
State of New Jersey } --------------
County of ______ M_o_rri_s ____ _ }
On ___ o_c_to_b_e_r_29_,_2_02_4 ___ before me, _____ A_nn_M_a_ri_e~K_e~a_ne---~- --· N_o_ta_ry_P_u_bl_ic __ (Here Insert name and title ol the officer)
personally appeared April o. Perez
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
I certify under PENAL TY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.
WITNESS my hand and official seal.
Notary Pub!icSign'!iture (Notary Public Seal)
ANN MARIE KEANE
NOTARY PUBLIC
STAT!! Of NEW JERSEY
MY COMMISSION EXPIRES MAY 19, 202S
4 My Commission Expires: May 19, 2025 •
lNSTRUCTIONS FOR COMPLETlNG THIS FORM
ADDITIONAL OPTIONAL INFORMATION This form compl ies ll'ith current California statures regarding notary wordin g and, DESCRIPTION OF THE A TT ACHED DOCUMENT if needed. should be comple ted and auached to the docum ent. Acknowledgments from other states may be completed for documents being .,en/ to that sta te so long as the ll'arding does not require the California notary, to violate California nota, y Performance and Payment Bonds Jaw.
(Title or description of attached document) • State and County infonnation must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signer(s) personally appeared which (TIiie or description of attached document continued) must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her Number of Pages _ _ Document Date 10/29/2024 commission followed by a comma and then your ti!le (notary public).
CAPACITY CLAIMED BY THE SIGNER
Ind ividual (s)
Corporate Office r
(Title)
Partner(s)
~ Attorney-in-Fact
Trustee(s)
Other _ ________ _
201'i Ver;,ion www NoiaryClasses con, 800-673-9865
• Print the name(s) or document signer(s) who personally appear at the lime of notarization.
• Indicate the correct singular or plural fonns by crossing off incorrect fonns (i.e. l!e/she/lhey;-is /01e) or circling the correct fonns. Failure to correctly indicate this infonnation may lead to rejection of document recording. • The notary seal impression must be clear and photographically reproducible.
Impression must not cover text or lines. If seal impression smudges, re-seal if a sufficient area pennits, otherwise complete a different acknowledgment form. • Signature of the notary public must match the signature on file with the office of the county clerk.
❖ Additional infonnation is not required but could help to ensure this acknowledgment is not misused or attached to a different document. ❖ Indicate title or type or attached document, number of pages and date. ❖ Indicate the capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO. Secretary). • Securely attach this document to the signed document with a staple.
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 65
No. B1-7939j-el
POWER OF A TIORNEY
BERKLEY INSURANCE COMPANY
WILMINGTON , DELAWARE
KNOW ALL MEN BY THESE PRESENTS, that BERKLEY INSURANCE COMPANY (the "Company") , a corporation duly organized and existing under the laws of the State of Delaware , having its principal office in Greenwich, CT, has made , constituted and appointed, and doe s by these presents make, constitute and appoint: Kristin S. Bender; A1111ette Audinot; Kelly O'Malley; April n. Perez; Jessica Jamrotta; Megan Schlueter; or A1111 Marie Kea11e of Marsh USA LLC of Morristown, NJ its trne and lawful Attorney-in-Fact, to sign its name as surety only as delineated below and to execute, seal, acknowledge and deliver any and all bonds and undertakings , with the exception of Financial Guaranty Insurance, providing that no single obligation shall exceed Fifty Million and 00/100 U.S. Dollars (U.S.$50,000,000.00), to the same extent as if such bonds had been duly executed and acknowledged by the regularly elected officers of the Company at its principal office in their own proper persons.
This Power of Attorney shall be construed and enforced in accordance with, and governed by, the laws of the State of Delaware , without giving effect to the principles of conflicts of laws thereof. This Power of Attorney is granted pursuant to the following resolutions which were duly and validly adopted at a meeting of the Board of Directors of the Company held on January 25, 2010:
RESOLVED , that, with respect to the Surety business written by Berkley Surety , the Chairman of the Board , Chief Executive Officer , President or any Vice President of the Company , in conjunction with the Secretary or any Assistant Secretary are hereby authorized to execute powers of attorney authorizing and qualifying the attorney-in-fact named therein to execute bonds , undertakings, recognizances, or other suretyship obligations on behalf of the Company, and to affix the corporate seal of the Company to powers of attorney executed pursuant hereto; and said officers may remove any such attorney-in-fact and revoke any power of attorney previously granted; and further RESOLVED , that sucb power of attorney limits the acts of those named therein to the bonds , undertakings , recognizances , or other suretyship obligations specifically named therein, and they have no authority to bind the Company except in the manner and to the extent therein stated; and further
RESOLVED that such power of attorney revokes all previous powers issued on behalf of the attorney-in-fact named; and further
RESOLVED, that the signature of any authorized officer and the seal of the Company may be affixed by facsimile to any power of attorn ey or certification thereof authorizing the execution and delivery of any bond, undertaking , recognizance , or other suretyship ob ligation of the Company; and such signature and seal when so used shall have the same force and effect as though manually affixed. The Company may continue to use for the purposes herein stated the facsimile signature of any person or persons who shall have been such officer or officers of the Company notwithstanding the fact that they may have ceased to be such at the time when such instruments shaU be issued.
IN Vv11NESS WHEREOF , the Company has caused these presents to be signed :rnd attested by its appropriate offl.c,ers and its corporate seal hereunto affixed this 2nd day of May , 2024 <~~-:,;A~;;--, Attest :_
-✓ ~ -------. (1 \ E;3 / :; f. o••O<U,:.. \ 0~ ·-, (l . \. ~ ( s~~L) ! J By ~L)8= , ,,1,. ,, 1 Philips _ elt
\., 4?~--;,.-;,.~'(. ,,. 1 Executive Vice Presideut & Secretary '·-·- -----·· Senior Vice President
STAil OF CONNECTICl:T)
) ss:
cot.~TY OF FAIRFU:LD )
Sworn to before me. a Notary Public in the State of Connecticut , this~ day of May 2024 , by Philip S. Welt and Jeffrey M. Hafter who are sworn to me to be the Executive Vice President and Secretary, and the Senior Vice President, respectively , of Berkley Insurance Company.
MARIA C. RLJNDBAKEN
HOTARr' PUBUC
CONNECTICUT
fKf COMMISSION E><PIRES o.HIG-.2029 CERTIFICATE
Notary Public, State of Connecticut
I. the undersigned , Assistant Secretary of BERKLEY INSURANCE COMP ANY, DO HEREBY CERTIFY that the foregoing is a true, correct and complete copy of the original Power of Attorney ; that said Power of Attorney has not been revoked or rescinded and ~a.t-th~ ... autbority of the Attorney-in-Fact set forth therein , who executed the bond or undertaking to which this Power of Aµo~~~cttl,:a~ hed, is in full force and effect a.s of this date _ :' $ /~o•P~-eibwder my hand and seal of the Company , this 29th day of October ,.,..- ~:--) . , 2024 . i ~ t' s1: lI i ~ I - - - - 1 · _j .v ---
•• ~ ·~ L .... ~ .. / ~ J I- ... , ~ : .... -: /.· (
-, ... tm_ / / I ,_rp;, .. } . ,A,)..., i _ - ~ / - --- ~n_.u_~··=--=---''--""---------, -°.:~~~:/ Vincent P_ For,e Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 66
Bond No. 0264629
PERFORMANCE BOND
KNOW ALL PERSONS BY THESE PRESENTS:
THAT WHEREAS, the City of Palm Springs (hereinafter referred to as "City") has awarded to Playcore Wisconsin, Inc., dba GameTime, (hereinafter referred to as the "Contractor") an agreement for Desert Highland Park Exercise Equipment Purchase and Installation (hereinafter referred to as the "Project").
WHEREAS, the work to be performed by the Contractor is more particularly set forth in the Contract Documents for the Project dated October 14, (hereinafter referred to as "Contract Documents"), the terms and conditions of which are expressly incorporated herein by reference; and WHEREAS , the Contractor is required by said Contract Documents to perform the terms thereof and to furnish a bond for the faithful performance of said Contract Documents.
NOW, THEREFORE, we, Playcore Wisconsin , Inc., dba GameTime, the undersigned Contractor and Berkley Insurance Company as Surety, a corporation organized and duly authorized to transact business under the laws of the State of California , are held and firmly bound unto the City in the sum of Sixty-Nine Thousand Thirty-Two Dollars and Thirty-Eight Cents, ($69,032.38), said sum being not less than one hundred percent (100%) of the total amount of the Contract, for which amount well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors and assigns, jointly and severally , firmly by these presents.
THE CONDITION OF THIS OBLIGATION IS SUCH, that, if the Contractor, his or its heirs, executors , administrators , successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and agreements in the Contract Documents and any alteration thereof made as therein provided, on its part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their intent and meaning; and shall faithfully fulfill all obligations including the one-year guarantee of all materials and workmanship; and shall indemnify and save harmless the City, its officers and agents, as stipulated in said Contract Documents , then this obligation shall become null and void; otherwise it shall be and remain in full force and effect.
As a condition precedent to the satisfactory completion of the Contract Documents, unless otherwise provided for in the Contract Documents , the above obligation shall hold good for a period of one (1) year after the acceptance of the work by City, during which time if Contractor shall fail to make full, complete, and satisfactory repair and replacements and totally protect the City from loss or damage resulting from or caused by defective materials or faulty workmanship, Surety shall undertake and faithfully fulfill all such obligations. The obligations of Surety hereunder shall continue so long as any obligation of Contractor remains. Nothing herein shall limit the City's rights or the Contractor or Surety's obligations under the Contract, law or equity, including, but not limited to, California Code of Civil Procedure section 337.15.
Whenever Contractor shall be, and is declared by the City to be, in default under the Contract Documents , the Surety shall remedy the default pursuant to the Contract Documents , or shall promptly, at the City's option:
Revised 4.13.23
S-S-57S-.18 I 65\'33503817.7
Exhibit F - 2 SH_QRT_F08M CONSTRUCTION CONTRA GT
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 67
Notary Acknowledgment
A notary public or other officer completing this
certificate verifies only the identity of the individual who signed the document to which this certificate is
attached, and not the truthfulness, accuracy, or validity of that document.
STATE OF ~~
COUNTYO ~u3 --;,,.L .. ~ ... Ir\ \c_
On Q::,,'\O~ ~o , 202.1-, before me, ~~l::'.\..V~ 0 • J personally
, Notary Public,
appeared t1AP:: lA C- ::IT2 r-J .,..:JS.O ~ , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. __ ,..._,,, ,,
~- fl.H · ll..a'I~ I certify under PENAL TY OF ~ ~ vR~.1!:f11~Jhe laws of the State of California that the foregoing paragraph is true and correct. ;_'-€,<¢/• ••••. d" ••
, Q ,• A .., ' f f ~o1 Ry \ \ WITNESS my hand and official seal. ' : -•- • w ji! ~d_Q ' ~,:, \ Pu '-'G i e:J f'J. '"' /"\ Signature of Not~blic B ,/ ~ § ~ • ~ ••• .,..,. -..,,,:, ~ ....... ~,...-~_~_-_-_-_-_-_-_-_-_-i_~_-_-_-_-_-_-_-_-_--:_-_-_-_-_-_-:....-_-_--- ••f 11,4"••·····--t;,."-.#
,,\ .... STAi":,--- OPTIONAL '""-~ ...... -
Though the information below is not required by law, it may prove valuable to persons relying on the document
and could prevent fraudulent removal and reattachment of this form to another document.
CAPACITY CLAIMED BY SIGNER
Individual
'&_ Corporate Officer
Co~-P 1r-"f2--\S-{!.-
Partner(s)
Title(s)
Limited
General
Attorney-In-Fact
Trustee(s)
Guardian/Conservator
Other:
Signer is representing:
Name Of Person(s) Or Entity(ies)
Revised 4.13.23
55575.18165\33505817. I
DESCRIPTION OF ATTACHED DOCUMENT
Title or Type of Document
C:::,
Number of Pages
-, {) hft I :1-1
Date of Document
Signer(s) Other Than Named Above
Exhi bit F - 5 SHORT FORM CONSTRUCTION CONTRACT
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 68
CALIFORNIA ALL- PURPOSE
CERTIFICATE OF ACKNOWLEDGMENT
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.
State of New Jersey
County of ______ M_o_rri_s ____ _
}
}
On ___ o_c_to_b_e_r 2_9_, _2_02_4 ___ before me 1 _____ A_nn_M_a_n_,·elT.KC:,eCT.ae":'ne=-==,=-:r.m::-:::r.,c::-:cm:' N,:co:;-ta_ry_P_u_bl_ic __ (Here Insert name end title of the officer)
personally appeared April D. Perez
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
I certify under PENAL TY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.
WITNESS my hand and official seal.
C ~
ANN MARIE KEAN E
NOTARY PUBU C
STAl'J: OF NEW JERSl!Y
Notar; PublicSig ature (Notary Public Seal) MY COMMISSION EXPIRES MAY 19. 202S .,.L>J!X Commission Expires: May 19, 2025 •
INSTRUCTIONS FOR COMPLETING THIS FORM
ADDITIONAL OPTIONAL INFORMATION 711isfor111 compli es with current California statut es regarding no1a1y wording and.
DESCRIPTION OF THE ATTACH ED DOCUMENT if needed, should be completed ond al/ached to r/re document. Acknowledgments from other states 1110)' be completed for documents being sent to that stale so long as the wording does not require the California notary to via/ate California notary Performance and Payment Bonds lmv.
(Title or description of attached document)
(Title or description of attached document continued)
Number of Pages __ Document Date 10/29/2024
CAPACITY CLAIMED BY THE SIGNER
Individual (s)
Corporate Officer
(Title)
D Partner(s)
~ Attorney-in-Fact
Trustee(s)
Other ____ _ ____ _
201 'i Ver,;1011 www NoImyClasses corn 800-673-9865
• State and County infonnation must be the Stale and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signer(s) personally appeared which must also be the same dale the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title (notary public). • Print the name(s) of document signer(s) who personally appear al the time of notarization.
• Indicate the correct singular or plural fonns by crossing off incorrect fonns (i.e. he/she/they, is /ere) or circling the correct forms. Failure to correctly indicate this information may lead to rejection of document recording. • The nolary seal impression must be clear and photographically reproducible.
Impression must not cover text or lines. If seal impression smudges, re-seal if a sufficient area permits, otherwise complete a different acknowledgment form. • Signature of the notary public must match the signature on file with the office of the county clerk.
❖ Additional infonnation is not required but could help to ensure this acknowledgment is not misused or attached to a different document. ❖ Indicate title or type of attached document, number of pages and date. ❖ Indicate the capacity claimed by the signer. If the claimed capacity is a corporare officer, indicate the title (i.e. CEO, CFO, Secretary). • Securely attach this document to the signed document with a staple.
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Item 1I - Page 69
No. BI- 7939j-el
POWER OF A TIORNEY
BERKLEY INSURANCE COMPANY
Wll.,MINGTON,DELAWARE
KNOW ALL MEN BY THESE PRESENTS , that BERKLEY INSURANCE COMPANY (the "Company"), a corporation duly organized and existing under the laws of the State of Delaware , having its principal office in Greenwich , CT, has made , constituted and appointed , and does by these presents make , constitute and appoint: Kristin S. Bender; Annette A11di11ot; Kelly O 'Malley; April D. Perez; Jessica la1111otta; Megan Schlueter; or A1111 Marie Kea11e of Marsh USA LLC of Morristown, NJ its true and lawful Attorney-in-Fact , to sign its name as surety only as delineated below and to execute, seal, acknowledge and deliver any and all bonds and undertakings , with the exception of Financial Guaranty Insurance , providing that no single obligation shall exceed Fifty Million and 00/100 U.S. Dollars (U.S.$50,000,000 .00), to the same extent as if such bonds had been duly executed and acknowledged by the regularly elected officers of the Company at its principal office in their own proper persons .
This Power of Attorney shall be construed and enforced in accordance with, and governed by, the laws of the State of Delaware , without giving effect to the principles of conflicts of laws thereof. This Power of Attorney is granted pursuant to the fo llowing resolutions which were duly and validly adopted at a meeting of the Board of Directors of the Company held on January 25, 2010:
RESOLVED, that with respect to the Surety business written by Berkley Surety , the Chairman of the Board , Chief Executive Officer , Pre sident or any Vice President of the Company, in conjunction with the Secreta1y or any Assistant Secretary are hereby authorized to execute powers of attorney authorizing and qualifying the attorney-in-fact named therein to execute bonds , undertakings, recognizances, or other suretyship obligations on behalf of the Company, and to affix the corporate seal of the Company to powers of attorney executed pursuant hereto; and said officers may remove any such attorney-in-fact and revoke any power of attorney previous ly granted; and further RESOLVED , that such power of attorney limits the acts of those named therein to the bonds, undertakings, recognizances , or other suretyship obligations specifically named therein , and they have no authority to bind the Company except in the manner and to the extent therein stated; and further
RESOLVED , that such power of attorney revokes all previous power s issued m1 behalf of the attorney-in-fact named; and further
RESOLVED, that the signature of any authorized officer and the seal of the Company may be affixed by facsimile to any power of attorney or ce1iification thereof authorizing the execution and delive1y of any bond , undertaking, recognizance, or other suretyship obligation of the Company; and such signature and seal when so used shall have the same force and effect as though manually affixed . The Company may continue to use for the purposes herei11 stated the facsimile signature of any person or per sons wbo sbaU have been such officer or officers of the Company, notwithstanding the fact that they may have ceased to be such at the time when such instruments shall be issued.
IN WITNESS \VHEREOF , the Company has caused these presents to be .signed and attested by its apprnpria1e officers and its corporate se.al hereunto affixed this 2nd day of May , 2024 , ;;"S~A;~-;-- Attest:.
I.,: / ~~,o;,;,0o~ \ (J \ .) (1._ff__ _
!~(.~b\L} ~l By \~i£>"" V0L \ >$) ·~, ,~r / " ./ Philip S_ elt ' .,.ji~~-;,,~_,, 1 Executive Vice President & Secretary ::;ah*
Senior Vice President
STATE OF CONNECTICUT)
) ss:
COQTY OF FAIRFIELD )
Sworn to before me, a Notary Public in the State of Connecticut , this~ day of May 2024 , by Philip S. Welt and Jeffrey M. Hafter who are sworn to me to be the Executive Vice President and Secretary, and the Senior Vice President, re-spectively. of Berkle y Insurance Company .
MARIA C. RLINDBAKEJ\I
NOTARY' PUBLIC
CONNECllCUT
MVCOMMISSfON E>f>IRES 04-S-.2029 CERTIFICATE
Notary Public , State ofConue.cticut
I. the undersigned , Assistant Secretary of BERKLEY INSURANCE COMPANY , DO HEREBY CERTIFY that the foregoing is a true, corre ct and complete copy of the original Power of Attorney; that said Power of Attorney has not been revoked or re.scinded and tt1a:t the. authority of the Attorney-in-Fact set forth !herein , who executed the bond or undertaking to which this Power of At16~~,i(a~~ hed, is in full force and effect as ofthis date. / ~ / ,P""'Crtri1,rb:1nder my hand a11d seal of the Company , this 29th day of October,.-~~.\ ,, , 2024 .. , s1· \l 1 ~ I { · ' -t ~ •• .. ~ .. / :i. / --~ "\ t ?l' , • "' . / ~ 1 I \ ., . \ \ .... ~~ , ~-.. i Wl,;i'°l.~ -- .. :J... '
~ <.:. , - .
'---. .. ~ ' Vincent P_ Forte
55575.18165\33505817.1
Revised 10.5.21 Exhibit G - 1 SHORT FORM CONSTRUCTION CONTRACT
EXHIBIT “G”
EXECUTIVE ORDER N-6-22 CERTIFICATION
Executive Order N -6-22 issued by Governor Gavin Newsom on March 4, 2022, directs all agencies and departments that are subject to the Governor’s authority to (a) terminate any contracts with any individuals or entities that are determined to be a target of economic sanctions against Russia and Russian entities and individuals; and (b) refrain from entering into any new contracts with such individuals or entities while the aforementioned sanctions are in effect.
Executive Order N-6-22 also requires that any contractor that: (1) currently has a contract with the City of Palm Springs funded through grant funds provided by the State of California; and/or (2) submits a bid or proposal or otherwise proposes to or enter into or renew a contract with the City of Palm Springs with State of California grant funds, certify that the person is not the target of any economic sanctions against Russia and Russian entities and individuals.
The contractor hereby certifies, SUBJECT TO PENALTY FOR PERJURY, that a) the contractor is not a target of any economic sanctions against Russian and Russian entities and individuals as discussed in Executive Order N -6-22 and b) the person signing below is duly authorized to legally bind the Contractor. This certification is made under the laws of the State of California.
Signature
Printed Name:
Title:
Firm Name:
Date:
Docusign Envelope ID: 49E7AB7A-D6E9-4FDC-9F63-0799573D05A4 Director of Sales Administration
11/4/2024
Clint Whiteside
PlayCore Wisconsin, Inc., DBA GameTime
Item 1I - Page 70
ATTACHMENT F
Item 1I - Page 71
Item 1I - Page 72
CITY OF PALM SPRINGS
SHORT FORM CONSTRUCTION CONTRACT 24C253
DESERT HIGHLAND PARK SURFACING IMPROVEMENTS
1. PARTIES AND DATE.
This Contract is made and entered into this 14th day of October 2024 by and between the City of Palm Springs, a California charter city and municipal corporation ("City") and Miracle Recreation Equipment Company, an Iowa corporation ("Contractor"). City and Contractor are sometimes individually referred to as "Party" and collectively as "Parties" in this Contract.
2. RECITALS.
2.1 City. City is a public agency organized under the laws of the State of California, with power to contract for services necessary to achieve its purpose.
2.2 Procurement. This contract is made and entered into in reference to the competitively solicited Sourcewell Contract #010521-L TS ("Cooperative Agreement").
2.3 Contractor. Contractor desires to perform and assume responsibility for the provision of certain construction services required by the City on the terms and conditions set forth in this Contract. Contractor represents that it is duly licensed and experienced in providing rubber surfacing improvements related construction services to public clients, that it and its employees or subcontractors have all necessary licenses and permits to perform the services in the State of California, and that it is familiar with the plans of City. The following license classifications are required for this Project: Class B
2.4 Project. City desires to engage Contractor to render such services for the Desert Highland Park Surfacing Improvements ("Project'') as set forth in this Contract.
2.5 Proiect Documents & Certifications. Contractor has obtained, and delivers concurrently herewith, payment and performance bonds, and insurance documents as required by the Contract.
3. TERMS
3.1 Compensation and Payment.
3.1.1 Amount of Compensation. As consideration for performance of the Work required herein, City agrees to pay Contractor the Total Contract Price of Seventy-Nine Thousand Sixty-Six Hundred Two Dollars ($79,662.00) ("Total Contract Price") provided that such amount shall be subject to adjustment pursuant to the applicable terms of this Contract or written change orders approved and signed in advance by the City.
3.1.2 Payment of Compensation. If the Work is scheduled for completion in thirty (30) or less calendar days, City will arrange for payment of the Total Contract Price upon completion and approval by City of the Work. If the Work is scheduled for completion in more than thirty (30) calendar days, City will pay Contractor on a monthly basis as provided for herein.
On or before the fifth (5th) day of each month, Contractor shall submit to the City an itemized application for payment in the format supplied by the City indicating the amount of Work completed Revised 10.5.21
55575 18165\33S05817. I
SHORT FORM CONSTRUCTION C~
Item 1I - Page 73
since commencement of the Work or since the last progress payment. These applications shall be supported by evidence which is required by this Contract and such other documentation as the City may require. The Contractor shall certify that the Work for which payment is requested has been done and that the materials listed are stored where indicated. Contractor may be required to furnish a detailed schedule of values upon request of the City and in such detail and form as the City shall request, showing the quantities, unit prices, overhead, profit, and all other expenses involved in order to provide a basis for determining the amount of progress payments.
3.1.3 Prompt Payment. City shall review and pay all progress payment requests in accordance with the provisions set forth in Section 20104.50 of the California Public Contract Code. However, no progress payments will be made for Work not completed in accordance with this Contract. Contractor shall comply with all applicable laws, rules and regulations relating to the proper payment of its employees, subcontractors, suppliers or others.
3.1.4 Contract Retentions. If this Contract is greater than Five Thousand dollars ($5,000), from each approved progress estimate, five percent (5%) will be deducted and retained by the City, and the remainder will be paid to Contractor. All Contract retention shall be released and paid to Contractor and subcontractors pursuant to California Public Contract Code Section 7107.
3.1.5 Other Retentions. In addition to Contract retentions, the City may deduct from each progress payment an amount necessary to protect City from loss because of:
( 1) liquidated damages which have accrued as of the date of the application for payment; (2) any sums expended by the City in performing any of Contractor's obligations under the Contract which Contractor has failed to perform or has performed inadequately; (3) defective Work not remedied; (4) stop notices as allowed by state law; (5) reasonable doubt that the Work can be completed for the unpaid balance of the Total Contract Price or within the scheduled completion date; (6) unsatisfactory prosecution of the Work by Contractor; (7) unauthorized deviations from the Contract; (8) failure of Contractor to maintain or submit on a timely basis proper and sufficient documentation as required by the Contract or by City during the prosecution of the Work; (9) erroneous or false estimates by Contractor of the value of the Work performed; (10) any sums representing expenses, losses, or damages as determined by the City, incurred by the City for which Contractor is liable under the Contract; and (11) any other sums which the City is entitled to recover from Contractor under the terms of the Contract or pursuant to state law, including Section 1727 of the California Labor Code. The failure by the City to deduct any of these sums from a progress payment shall not constitute a waiver of the City's right to such sums.
3.1.6 Substitutions for Contract Retentions. Pursuant to California Public Contract Code section 22300, Contractor may substitute securities for any money withheld by the City to ensure the performance under the Contract. At the request and expense of Contractor, securities equivalent to the amount withheld shall be deposited with the City, with the State or a federally chartered bank as the escrow agent. who shall return such securities to Contractor upon satisfactory completion of the Contract. Deposit of securities with an escrow agent shall be subject to a written agreement between the escrow agent and the City, which provides that no portion of the securities shall be paid to Contractor until the City has certified to the escrow agent, in writing, that the Contract has been satisfactorily completed. The City shall certify that the Contract has been satisfactorily completed within sixty (60) days of work "completion" as defined in Section 7107(c) of the California Public Contract Code. Securities eligible for investment under this section shall be limited to those listed in Section 16430 of the Government Code, bank or savings & loan certificates of deposit, interest-bearing demand deposit accounts, stand-by letters of credit, or any other security mutually agreed to by Contractor.
Revised 10.5.21
5557S.18165\3350S8 I 7.1
2 SHORT FORM CONSTRUCTION CONTRA~
Item 1I - Page 74
3.1. 7 Payment to Subcontractors. Contractor shall pay all subcontractors for and on account of work performed by such subcontractors in accordance with the terms of their respective subcontracts and as provided for in Section 7108.5 of the California Business and Professions Code. Such payments to subcontractors shall be based on the measurements and estimates made and progress payments provided to Contractor pursuant to this Contract.
3.1.8 Title to Work. As security for partial, progress, or other payments, title to Work for which such payments are made shall pass to the City at the time of payment. To the extent that title has not previously been vested in the City by reason of payments, full title shall pass to the City at delivery of the Work at the destination and time specified in this Contract. Such transferred title shall in each case be good, free and clear from any and all security interests, liens, or other encumbrances. Contractor promises and agrees that it will not pledge, hypothecate, or otherwise encumber the items in any manner that would result in any lien, security interest, charge, or claim upon or against said items. Such transfer of title shall not imply acceptance by the City, nor relieve Contractor from the responsibility to strictly comply with the Contract, and shall not relieve Contractor of responsibility for any loss of or damage to items.
3.1.9 Labor and Material Releases. Contractor shall furnish City with labor and material releases from all subcontractors performing work on, or furnishing materials for, the Work governed by this Contract prior to final payment by City.
3.2 Incorporation of Documents. This Contract includes and hereby incorporates in full by reference the following documents, including all exhibits, drawings, specifications and documents therein, and attachments and addenda thereto:
• Services/Schedule (Exhibit "A")
• Schedule of Compensation (Exhibit "B")
• Special Conditions (Exhibit "C")
• Contractor's Certificate Regarding Workers' Compensation (Exhibit "D") • Public Works Contractor Registration Certification (Exhibit "E") • Payment and Performance Bonds (Exhibit "F")
• Executive Order N-6-22 Certification (Exhibit "G")
• Change Orders executed by the City
To the extent there is a conflict between any portions of this Contract, the order of precedence shall be as follows: change orders, special conditions, technical specifications, plans/construction drawings, general contract terms, scope of work, standard plans, advertisements for bid/proposals, bids/proposals or other documents submitted by Contractor.
3.3 Contractor's Basic Obligation; Scope of Work.
3.3.1 Scope of Work. Contractor promises and agrees, at its own cost and expense, to furnish to the City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately complete the Project, including all structures and facilities necessary for the Project or described in the Contract (hereinafter sometimes referred to as the "Work"), for a Total Contract Price as specified pursuant to this Contract. All Work shall be subject to, and performed in accordance with the above referenced documents, as well as the exhibits attached hereto and incorporated herein by reference. The plans and specifications for the Work are further described in Exhibit "B" attached hereto and incorporated herein by this reference. Special Conditions, if any, relating to the Work are described in Exhibit "C" attached hereto and incorporated herein by this reference.
Revised 10.5.21
55575.18165\335058l 7. I
3 SHORT FORM CONSTRUCTION CONTRA"@
Item 1I - Page 75
3.3.2 Change in Scope of Work. Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition or deletion is approved in advance and in writing by a valid change order executed by the City.
3.3.3 Change Orders. Changes to the Contract Time (as defined in Section
3.3) or Total Contract Price shall be in the form of a written Change Order, either signed by both parties or issued unilaterally by the City. No adjustment shalt be made to the Contract Time unless the delay impacts the critical path to completion and the delay was not caused in whole or in part by the Contractor. The City's liability to Contractor for delays for which the City is responsible shall be limited to only an extension of time unless such delays were unreasonable under the circumstances. Failure to timely request a Change Order shall constitute a waiver of any right to adjust the Contract Time or the Total Contract Price. All requests for Change Orders shall be accompanied by detailed supporting documentation, including but not limited to payroll records, invoices, schedules, and any other documentation requested by the City for the purpose of determining the additional costs or the impact of any delay. If the change involves Work bid at a unit price, then the Total Contract Price shall be increased at the unit price. If there is no unit price, then the Total Contract Price shall be adjusted to account for costs actually incurred plus an allowed mark-up of fifteen percent (15%), which shall constitute the entire amount of profit, mark ups, field or home office overhead costs, including personnel, equipment or office space, any materials, or any costs of equipment idle time for such work. Regardless of ownership, equipment rates shall not exceed the listed prevailing rates at local equipment rental agencies, or distributors, at the time the work is performed. Nothing herein shall prevent the Parties from agreeing to a lump sum cost.
3.3.4 Changes Ordered By City. City may at any time issue a written directive ordering additions, deletions, or changes to the Work. Contractor shall proceed with the work in accordance with the directive. To the extent the directive results in extra work or requires additional Contract Time, Contractor shall request a Change Order within seven (7) days of receiving the Work Directive. If any costs are not capable of being determined within seven (7) days, then Contractor shall request a Change Order within seven (7) days of when the costs are capable of being determined.
3.3.5 Changes Requested By Contractor. With respect to any matter that may involve or require an adjustment to the Contract Time or the Contract Price, Contractor shall provide written notice of the underlying facts and circumstances that gave rise to the potential change within seven (7) days or prior to the alteration of conditions, whichever is earlier. Failure to give notice shall constitute a waiver of Contractor's right to a change order. If any costs are not capable of being determined within seven (7) days, then Contractor shall request a Change Order within seven (7) days of when the costs are capable of being determined.
3.4 Substitutions/"Or Equal". Pursuant to Public Contract Code Section 3400(b), the City may make a finding that designates certain products, things, or services by specific brand or trade name. Unless specifically designated in this Contract, whenever any material, process, or article is indicated or specified by grade, patent, or proprietary name or by name of manufacturer, such Specifications shall be deemed to be used for the purpose of facilitating the description of the material, process or article desired and shall be deemed to be followed by the words "or equal."
Contractor may, unless otherwise stated, offer for substitution any material, process or Revised 10.5.21
55575.18165\33505817 I
4 SHORT FORM CONSTRUCTION CONTRAW
Item 1I - Page 76
article which shall be substantially equal or better in every respect to that so indicated or specified in this Contract. However, the City may have adopted certain uniform standards for certain materials, processes and articles. Contractor shall submit requests, together with substantiating data, for substitution of any "or equal" material, process or article no later than thirty-five (35) days after award of the Contract. To facilitate the construction schedule and sequencing, some requests may need to be submitted before thirty-five (35) days after award of Contract. Provisions regarding submission of "or equal" requests shall not in any way authorize an extension of time for performance of this Contract. If a proposed "or equal" substitution request is rejected, Contractor shall be responsible for providing the specified material, process or article. The burden of proof as to the equality of any material, process or article shall rest with Contractor.
The City has the complete and sole discretion to determine if a material, process or article is an "or equal" material, process or article that may be substituted. Data required to substantiate requests for substitutions of an "or equal" material, process or article data shall include a signed affidavit from Contractor stating that, and describing how, the substituted "or equal" material, process or article is equivalent to that specified in every way except as listed on the affidavit.
Substantiating data shall include any and all illustrations, specifications, and other relevant data including catalog information which describes the requested substituted "or equal" material, process or article, and substantiates that it is an "or equal" to the material, process or article. The substantiating data must also include information regarding the durability and lifecycle cost of the requested substituted "or equal" material, process or article. Failure to submit all the required substantiating data, including the signed affidavit, to the City in a timely fashion will result in the rejection of the proposed substitution.
Contractor shall bear all of the City's costs associated with the review of substitution requests. Contractor shall be responsible for all costs related to a substituted "or equal" material, process or article. Contractor is directed to the Special Conditions (if any) to review any findings made pursuant to Public Contract Code section 3400.
3.5 Period of Performance and Liquidated Damages.
3.5.1 Contractor shall perform and complete all Work under this Contract within 50 working days, beginning the effective date of the Notice to Proceed ("Contract Time").
Contractor shall perform its Work in strict accordance with any completion schedule, construction schedule or project milestones developed by the City. Such schedules or milestones may be included as part of Exhibits "A" or "B" attached hereto, or may be provided separately in writing to Contractor. Contractor agrees that if such Work is not completed within the aforementioned Contract Time and/or pursuant to any such completion schedule, construction schedule or project milestones developed pursuant to provisions of the Contract, it is understood, acknowledged and agreed that the City will suffer damage. Pursuant to Government Code Section 53069.85, Contractor shall pay to the City as fixed and liquidated damages the sum of Seventy-Nine Thousand Six Hundred Sixty-Two Dollars ($79,662.00) per day for each and every calendar day of delay beyond the Contract Time or beyond any completion schedule, construction schedule or Project milestones established pursuant to the Contract.
3.5.2 If Contractor is delayed in the performance or progress of the Work by a Force Majeure Event (as defined herein), then the Contractor shall be entitled to a time Revised 10.5 21
55575.18165\3350S817.1
5 SHORT FORM CONSTRUCTION CONT"{[)
Item 1I - Page 77
extension, as provided herein, when the Work stopped is on the critical path and shall not be charged liquidated damages. Such a non-compensable adjustment shall be Contractor's sole and exclusive remedy for such delays and the Contractor will not receive an adjustment to the Total Contract Price or any other compensation. Contractor must submit a timely request in accordance with the requirements of the Contract.
3.5.3 A Force Majeure Event shall mean an event that materially affects a party's performance and is one or more of the following: (1) Acts of God or other natural disasters occurring at the project site; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the work); (4) pandemics, epidemics or quarantine restrictions; and (5) strikes and other organized labor action occurring at the project site and the effects thereof on the work, only to the extent such strikes and other organized labor action are beyond the control of Contractor and its subcontractors, of every tier, and to the extent the effects thereof cannot be avoided by use of replacement workers. For purposes of this section, "orders of governmental authorities," includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of the City in its capacity as a municipal authority.
3.6 Standard of Performance; Performance of Employees. Contractor shall perform all Work under this Contract in a skillful and workmanlike manner, and consistent with the standards generally recognized as being employed by professionals in the same discipline in the State of California. Contractor represents and maintains that it is skilled in the professional calling necessary to perform the Work. Contractor warrants that all employees and subcontractors shall have sufficient skill and experience to perform the Work assigned to them.
Finally, Contractor represents that it, its employees and subcontractors have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Work, including a City Business License, and that such licenses and approvals shall be maintained throughout the term of this Contract. As provided for in the indemnification provisions of this Contract, Contractor shall perform, at its own cost and expense and without reimbursement from the City, any work necessary to correct errors or omissions which are caused by Contractor's failure to comply with the standard of care provided for herein. Any employee who is determined by the City to be uncooperative, incompetent, a threat to the safety of persons or the Work, or any employee who fails or refuses to perform the Work in a manner acceptable to the City, shall be promptly removed from the Project by Contractor and shall not be re-employed on the Work.
3.7 Control and Payment of Subordinates; Contractual Relationship. City retains Contractor on an independent contractor basis and Contractor is not an employee of City. Any additional personnel performing the work governed by this Contract on behalf of Contractor shall at all times be under Contractor's exclusive direction and control. Contractor shall pay all wages, salaries, and other amounts due such personnel in connection with their performance under this Contract and as required by law. Contractor shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, and workers' compensation insurance.
3.8 City's Basic Obligation. City agrees to engage and does hereby engage Contractor as an independent contractor to furnish all materials and to perform all Work according to the terms and conditions herein contained for the sum set forth above. Except as otherwise provided in the Contract, the City shall pay to Contractor, as full consideration for the satisfactory performance by Contractor of the services and obligations required by this Contract, the below referenced compensation in accordance with compensation provisions set forth in the Contract.
Revised 10.5.21
55575.18165\33505817 l
6 SHORT FORM CONSTRUCTION CONTRi{}J
Item 1I - Page 78
3.9 Labor.
3.9.1 Prevailing Wages. Contractor is aware of the requirements of California Labor Code Section 1720 et seq., and 1770 et seq., as well as California Code of Regulations, Title 8, Section 16000 et seq., ("Prevailing Wage Laws"), which require the payment of prevailing wage rates and the performance of other requirements on "public works" and "maintenance" projects. Since the Work is being performed as part of an applicable "public works" or "maintenance" project, as defined by the Prevailing Wage Laws, and if the total compensation is $15,000 or more for maintenance or $25,000 or more for construction, alteration, demolition, installation, or repair, Contractor agrees to fully comply with such Prevailing Wage Laws. City shall provide Contractor with a copy of the prevailing rates of per diem wages in effect at the commencement of this Contract. Contractor shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services available to interested parties upon request, and shall post copies at Contractor's principal place of business and at the project site. Contractor shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws. Contractor and any subcontractor shall forfeit a penalty of up to $200 per calendar day or portion thereof for each worker paid less than the prevailing wage rates.
3.9.2 Apprenticeable Crafts. When Contractor employs workmen in an apprenticeable craft or trade, Contractor shall comply with the provisions of Section 1777 .5 of the California Labor Code with respect to the employment of properly registered apprentices upon public works. The primary responsibility for compliance with said section for all apprenticeable occupations shall be with Contractor. The Contractor or any subcontractor that is determined by the Labor Commissioner to have knowingly violated Section 1777 .5 shall forfeit as a civil penalty an amount not exceeding $100 for each full calendar day of noncompliance, or such greater amount as provided by law.
3.9.3 Hours of Work. Contractor is advised that eight (8) hours labor constitutes a legal day's work. Pursuant to Section 1813 of the California Labor Code, Contractor shall forfeit a penalty of $25.00 per worker for each day that each worker is permitted to work more than eight (8) hours in any one calendar day and forty (40) hours in any one calendar week, except when payment for overtime is made at not less than one and one-half ( 1-1 /2) times the basic rate for that worker.
3.9.4 Payroll Records. Contractor and each subcontractor shall keep an accurate payroll record, showing the name, address, social security number, work classification, straight time and overtime hours worked each day and week, and the actual per diem wages paid to each journeyman, apprentice, worker, or other employee employed by him or her in connection with the public work. The payroll records shall be certified and shall be available for inspection at all reasonable hours at the principal office of Contractor in the manner provided in Labor Code section 1776. In the event of noncompliance with the requirements of this section, Contractor shall have 1 0 days in which to comply subsequent to receipt of written notice specifying in what respects such Contractor must comply with this section. Should noncompliance still be evident after such 10-day period, Contractor shall, as a penalty to City, forfeit not more than $100.00 for each calendar day or portion thereof, for each worker, until strict compliance is effectuated. The amount of the forfeiture is to be determined by the Labor Commissioner. A contractor who is found to have violated the provisions of law regarding wages on Public Works with the intent to defraud shall be ineligible to bid on Public Works contracts for a period of one to three years as determined by the Labor Commissioner. Upon the request of the Division of Apprenticeship Revised 10.5.21
55515 18165\33505817 I
7 SHORT FORM CONSTRUCTION CONTt
Item 1I - Page 79
Standards or the Division of Labor Standards Enforcement, such penalties shall be withheld from progress payments then due. The responsibility for compliance with this section is on Contractor.
In accordance with Labor Code section 1771.4, the Contractor and each subcontractor shall furnish the certified payroll records directly to the Department of Industrial Relations ("DIR") on a weekly basis and in the format prescribed by the DIR, which may include electronic submission.
The requirement to submit certified payroll records directly to the Labor Commissioner under Labor Code section 1771.4 shall not apply to work performed on a public works project that is exempt pursuant to the small project exemption specified in Labor Code Section 1771.4.
3.9.5 Contractor and Subcontractor Registration. Pursuant to Labor Code sections 1725.5 and 1771.1, all contractors and subcontractors that wish to bid on, be listed in a bid proposal, or enter into a contract to perform public work must be registered with the DIR. No bid will be accepted nor any contract entered into without proof of the contractor's and subcontractors' current registration with the DIR to perform public work. Contractor is directed to review, fill out and execute the Public Works Contractor Registration Certification attached hereto as Exhibit "E" prior to contract execution. Notwithstanding the foregoing, the contractor registration requirements mandated by Labor Code Sections 1725.5 and 1771.1 shall not apply to work performed on a public works project that is exempt pursuant to the small project exemption specified in Labor Code Sections 1725.5 and 1771.1.
3.9.6 Labor Compliance; Stop Orders. This Project is subject to compliance monitoring and enforcement by the DIR. It shall be the Contractor's sole responsibility to evaluate and pay the cost of complying with all labor compliance requirements under this Contract and applicable law. Any stop orders issued by the DIR against Contractor or any subcontractor that affect Contractor's performance of Work, including any delay, shall be Contractor's sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Contractor caused delay subject to any applicable liquidated damages and shall not be compensable by the City. Contractor shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the DIR against Contractor or any subcontractor.
3.10 Performance of Work; Jobsite Obligations.
3.10.1 Water Quality Management and Compliance.
3.10.1.1 Water Quality Management and Compliance. Contractor shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Work including, without limitation, all applicable provisions of the Federal Water Pollution Control Act (33 U.S.C. §§ 1300); the California Porter-Cologne Water Quality Control Act (Cal Water Code§§ 13000-14950); local ordinances regulating discharges of storm water; and any and all regulations, policies, or permits issued pursuant to any such authority regulating the discharge of pollutants, as that term is used in the Porter-Cologne Water Quality Control Act, to any ground or surface water in the State.
3.10.1.2 Compliance with the Statewide Construction General Permit.
Contractor shall comply with all conditions of the most recent iteration of the National Pollutant Discharge Elimination System General Permit for Storm Water Discharges Associated with Construction Activity, issued by the California State Water Resources Control Board ("Permit"). It shall be Contractor's sole responsibility to file a Notice of Intent and procure coverage under the Permit for all construction activity which results in the disturbance of more than one acre of total Revised 10.5.21 8 SHORT FORM CONSTRUCTION CONTRA
55575 18165\33505817 I
Item 1I - Page 80
land area or which is part of a larger common area of development or sale. Prior to initiating work, Contractor shall be solely responsible for preparing and implementing a Storm Water Pollution Prevention Plan (SWPPP) as required by the Permit. Contractor shall be responsible for procuring, implementing and complying with the provisions of the Permit and the SWPPP, including the standard provisions, and monitoring and reporting requirements as required by the Permit. The Permit requires the SWPPP to be a "living document" that changes as necessary to meet the conditions and requirements of the job site as it progresses through difference phases of construction and is subject to different weather conditions. It shall be Contractor's sole responsibility to update the SWPPP as necessary to address conditions at the project site.
3.10.1.3 Other Water Quality Rules Regulations and Policies. Contractor shall comply with the lawful requirements of any applicable municipality, drainage City, or local agency regarding discharges of storm water to separate storm drain systems or other watercourses under their jurisdiction, including applicable requirements in municipal storm water management programs.
3.10.1.4 Cost of Compliance. Storm, surface, nuisance, or other waters may be encountered at various times during construction of the Work. Therefore, the Contractor, hereby acknowledges that it has investigated the risk arising from such waters and assumes any and all risks and liabilities arising therefrom.
3.10.1.5 Liability for Non-Compliance. Failure to comply with 1aws, regulations, standards, ordinances, and permits listed in Sections 3.10.1.1, 3.10.1.2, 3.10.1.3, and 3.10.1.4 of the Contract is a violation of federal and state law. Pursuant to the indemnification provisions of this Contract, Contractor hereby agrees to defend, indemnify and hold harmless the City and its directors, officials, officers, employees, volunteers and agents for any alleged violations. In addition, City may seek damages from Contractor for any delay in completing the Work in accordance with the Contract. if such delay is caused by or related to Contractor's failure to comply with the Permit.
3.10.1.6 Reservation of Right to Defend. City reserves the right to defend any enforcement action brought against the City for Contractor's failure to comply with the Permit or any other relevant water quality law, regulation, or policy. Pursuant to the indemnification provisions of this Contract, Contractor hereby agrees to be bound by, and to reimburse the City for the costs (including the City's attorney's fees) associated with, any settlement reached between the City and the relevant enforcement entity.
3.10.1.7 Training. In addition to the standard of performance requirements set forth in this Contract, Contractor warrants that all employees and subcontractors shall have sufficient skill and experience to perform the work assigned to them without impacting water quality in violation of the laws, regulations and policies described in paragraph 3.10.1.
Contractor further warrants that it, its employees and subcontractors will receive adequate training, as determined by City. regarding the requirements of the laws, regulations and policies described in paragraph 3.10.1 as they may relate to the Work provided under this Contract. Upon request, City will provide the Contractor with a list of training programs that meet the requirements of this paragraph.
3.10.2 Safety. Contractor shall execute and maintain its work so as to avoid injury or damage to any person or property. Contractor shall comply with the requirements of the specifications relating to safety measures applicable in particular operations or kinds of work. In carrying out its Work, Contractor shall at all times be in compliance with all applicable local, state Revised 10.5.21
55575.18165\33505817. I
9 SHORT FORM CONSTRUCTION CONTRA~
Item 1I - Page 81
and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of employees appropriate to the nature of the Work and the conditions under which the Work is to be performed. Safety precautions as applicable shall include, but shall not be limited to, adequate life protection and lifesaving equipment; adequate illumination for underground and night operations; instructions in accident prevention for all employees, such as machinery guards, safe walkways, scaffolds, ladders, bridges, gang planks, confined space procedures, trenching and shoring, fall protection and other safety devices, equipment and wearing apparel as are necessary or lawfully required to prevent accidents or injuries; and adequate facilities for the proper inspection and maintenance of all safety measures. Furthermore, Contractor shall prominently display the names and telephone numbers of at least two medical doctors practicing in the vicinity of the Project, as well as the telephone number of the local ambulance service, adjacent to all telephones at the Project site.
3.10.3 Laws and Regulations. Contractor shall keep itself fully informed of and in compliance with all local, state and federal laws, rules and regulations in any manner affecting the performance of the Contract or the Work, including all Cal/OSHA requirements, and shall give all notices required by law. Contractor shall be liable for all violations of such laws and regulations in connection with the Work. If Contractor observes that the drawings or specifications are at variance with any law, rule or regulation, it shall promptly notify the City in writing. Any necessary changes shall be made by written change order. If Contractor performs any work knowing it to be contrary to such laws, rules and regulations and without giving written notice to the City, Contractor shall be solely responsible for all costs arising therefrom. City is a public entity of the State of California subject to certain provisions of the Health & Safety Code, Government Code, Public Contract Code, and Labor Code of the State. It is stipulated and agreed that all provisions of the law applicable to the public contracts of a municipality are a part of this Contract to the same extent as though set forth herein and will be complied with. Contractor shall defend, indemnify and hold City, its officials, directors, officers, employees and agents free and harmless, pursuant to the indemnification provisions of this Contract, from any claim or liability arising out of any failure or alleged failure to comply with such laws, rules or regulations.
3.10.4 Permits and Licenses. Contractor shall be responsible for securing City permits and licenses necessary to perform the Work described herein, including, but not limited to, a City Business License. While Contractor will not be charged a fee for any City permits, Contractor shall pay the City's applicable business license fee. Any ineligible contractor or subcontractor pursuant to Labor Code Sections 1777 .1 and 1777. 7 may not perform work on this Project.
3.10.5 Trenching Work. If the Total Contract Price exceeds $25,000 and if the Work governed by this Contract entails excavation of any trench or trenches five (5) feet or more in depth, Contractor shall comply with all applicable provisions of the California Labor Code, including Section 6705. To this end, Contractor shall submit for City's review and approval a detailed plan showing the design of shoring, bracing, sloping, or other provisions to be made for worker protection from the hazard of caving ground during the excavation of such trench or trenches. If such plan varies from the shoring system standards, the plan shall be prepared by a registered civil or structural engineer.
3.10.6 Hazardous Materials and Differing Conditions. As required by California Public Contract Code Section 7104, if this Contract involves digging trenches or other excavations that extend deeper than four (4) feet below the surface, Contractor shall promptly, and prior to disturbance of any conditions, notify City of: (1) any material discovered in excavation that Contractor believes to be a hazardous waste that is required to be removed to a Class I, Class II Revised 10.5.21
55575.1Sl65\33505Sl7 I
10 SHORT FORM CONSTRUCTION COITTRAil/
Item 1I - Page 82
or Class Ill disposal site; (2) subsurface or latent physical conditions at the site differing from those indicated by City; and (3) unknown physical conditions of an unusual nature at the site, significantly different from those ordinarily encountered in such contract work. Upon notification, City shall promptly investigate the conditions to determine whether a change order is appropriate.
In the event of a dispute, Contractor shall not be excused from any scheduled completion date and shall proceed with all Work to be performed under the Contract, but shall retain all rights provided by the Contract or by law for making protests and resolving the dispute.
3.10.7 Underground Utility Facilities. To the extent required by Section 4215 of the California Government Code, City shall compensate Contractor for the costs of: (1) locating and repairing damage to underground utility facilities not caused by the failure of Contractor to exercise reasonable care; (2) removing or relocating underground utility facilities not indicated in the construction drawings; and (3) equipment necessarily idled during such work. Contractor shall not be assessed liquidated damages for delay caused by failure of City to provide for removal or relocation of such utility facilities.
3.10.8 Air Quality. Contractor must fully comply with all applicable laws, rules and regulations in furnishing or using equipment and/or providing services, including, but not limited to, emissions limits and permitting requirements imposed by the California Air Resources Board (CARB). Although CARB limits and requirements are more broad, Contractor shall specifically be aware of their application to "portable equipment", which definition is considered by CARS to include any item of equipment with a fuel-powered engine. Contractor shall indemnify City against any fines or penalties imposed by CARS, or any other governmental or regulatory agency for violations of applicable laws, rules and/or regulations by Contractor, its subcontractors, or others for whom Contractor is responsible under its indemnity obligations provided for in this Contract.
3.10.9 State Recycling Mandates. Contractor shall comply with State Recycling Mandates. Any recyclable materials/debris collected by the contractor that can be feasibly diverted via reuse or recycling must be hauled by the appropriate handler for reuse or recycling.
3.10 .10 Inspection Of Site. Contractor has visited sites where Work is to be performed and has become acquainted with all conditions affecting the Work. Contractor warrants that it has made such examinations as it deems necessary to determine the condition of the Work sites, its accessibility to materials, workmen and equipment, and to determine the Contractor's ability to protect existing surface and subsurface improvements. No claim for allowances-time or money-will be allowed as to such matters.
3.10.11 Field Measurements. Contractor shall make field measurements, verify field conditions and shall carefully compare such field measurements and conditions and other information known to Contractor with the Contract Documents before commencing activities.
Errors, inconsistencies or omissions discovered shall be reported to the City immediately and prior to performing any work or altering the condition.
3.11 Completion of Work. When Contractor determines that it has completed the Work required herein, Contractor shall so notify City in writing and shall furnish all labor and material releases required by this Contract. City shall thereupon inspect the Work. If the Work is not acceptable to the City, the City shall indicate to Contractor in writing the specific portions or items of Work which are unsatisfactory or incomplete. Once Contractor determines that it has completed the incomplete or unsatisfactory Work, Contractor may request a re-inspection by the Revised 10.5.21
55575.18165\335058 I 7 I
11 SHORT FORM CONSTRUCTION CONTRA'
Item 1I - Page 83
City. Once the Work is acceptable to City, City shall pay to Contractor the Total Contract Price remaining to be paid, less any amount which City may be authorized or directed by law to retain.
Payment of retention proceeds due to Contractor shall be made in accordance with Section 7107 of the California Public Contract Code.
3.12 Claims; Government Code Claim Compliance.
3.12.1 Intent. Effective January 1, 1991, Section 20104 et seq., of the California Public Contract Code prescribes a process utilizing informal conferences, non-binding judicial supervised mediation, and judicial arbitration to resolve disputes on construction claims of $375,000 or less. Effective January 1, 2017, Section 9204 of the Public Contract Code prescribes a process for negotiation and mediation to resolve disputes on construction claims.
The intent of this Section is to implement Sections 20104 et seq. and Section 9204 of the California Public Contract Code. This Section shall be construed to be consistent with said statutes.
3.12.2 Claims. For purposes of this Section, "Claim" means a separate demand by the Contractor, after a change order duly requested in accordance with the terms of this Contract has been denied by the City, for (A) a time extension, (B) payment of money or damages arising from Work done by or on behalf of the Contractor pursuant to the Contract, or (C) an amount the payment of which is disputed by the City. A "Claim" does not include any demand for payment for which the Contractor has failed to provide notice, request a change order, or otherwise failed to follow any procedures contained in the Contract Documents.
3.12.3 Filing Claims. Claims governed by this Section may not be filed unless and until the Contractor completes all procedures for giving notice of delay or change and for the requesting of a time extension or change order, including but not necessarily limited to the change order procedures contained herein, and Contractor's request for a change has been denied in whole or in part. Claims governed by this Section must be filed no later than fourteen (14) days after a request for change has been denied in whole or in part or after any other event giving rise to the Claim. The Claim shall be submitted in writing to the City and shall include on its first page the following in 16 point capital font: "THIS IS A CLAIM." Furthermore, the claim shall include the documents necessary to substantiate the claim. Nothing in this Section is intended to extend the time limit or supersede notice requirements otherwise provided by contract for the filing of claims, including all requirements pertaining to compensation or payment for extra Work, disputed Work, and/or changed conditions. Failure to follow such contractual requirements shall bar any claims or subsequent lawsuits for compensation or payment thereon.
3.12.4 the following format:
Supporting Documentation. The Contractor shall submit all claims in
3.12.4.1 Summary of claim merit and price, reference Contract Document provisions pursuant to which the claim is made Revised 10.5.21
55575.18165\33505811.I
3.12.4.2 List of documents relating to claim:
(A) Specifications
(B) Drawings
(C) Clarifications (Requests for Information)
12 SHORT FORM CONSTRUCTION CONTRA@
Item 1I - Page 84
documents
(D) Schedules
(E) Other
3.12.4.3 Chronology of events and correspondence
3.12.4.4 Analysis of claim merit
3.12.4.5 Analysis of claim cost, including calculations and supporting
3.12.4.6 Time impact analysis in CPM format
3.12.5 City's Response. Upon receipt of a Claim pursuant to this Section, City shall conduct a reasonable review of the Claim and, within a period not to exceed 45 days of receipt of the Claim, or as extended by mutual agreement, shall provide the Contractor a written statement identifying what portion of the Claim is disputed and what portion is undisputed. Any payment due on an undisputed portion of the Claim will be processed and made within 60 days after the City issues its written statement.
3.12.5.1 If City needs approval from its governing body to provide the Contractor a written statement identifying the disputed portion and the undisputed portion of the Claim, and the governing body does not meet within the 45 days or within the mutually agreed to extension of time following receipt of a Claim sent by registered mail or certified mail, return receipt requested, City shall have up to three (3) days following the next duly publicly noticed meeting of the governing body after the 45-day period, or extension, expires to provide the Contractor a written statement identifying the disputed portion and the undisputed portion.
3.12.5.2 Within 30 days of receipt of a Claim, City may request in writing additional documentation supporting the Claim or relating to defenses or claims City may have against the Contractor. If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement of City and the Contractor. City's written response to the Claim, shall be submitted to the Contractor within 30 Days (if the Claim is less than $50,000, within 15 Days) after receipt of the additional documentation, or within a period of time no greater than that taken by the Contractor in producing the additional information or requested documentation, whichever is greater.
3.12.6 Meet and Confer. If the Contractor disputes City's written response, or City fails to respond within the time prescribed, the Contractor may so notify City, in writing, within 15 Days of receipt of City's response or the City's failure to respond, and demand an informal conference to meet and confer for settlement of the issues in dispute. Upon receipt of a demand, City shall schedule a meet and confer conference within 30 Days for settlement of the dispute.
3.12.7 Mediation. Within 10 business days following the conclusion of the meet and confer conference, if the Claim or any portion of the Claim remains in dispute, City shall provide the Contractor a written statement identifying the portion of the Claim that remains in dispute and the portion that is undisputed. Any payment due on an undisputed portion of the Claim shall be processed and made within 60 Days after City issues its written statement. Any disputed portion of the Claim, as identified by the Contractor in writing, shall be submitted to non binding mediation, with City and the Contractor sharing the associated costs equally. City and Contractor Revised 10.5.21 13
55575 18 I 65\33505817 I
Item 1I - Page 85
shall mutually agree to a mediator within 10 business days after the disputed portion of the Claim has been identified in writing, unless the Parties agree to select a mediator at a later time.
3.12.7.1 If the Parties cannot agree upon a mediator, each Party shall select a mediator and those mediators shall select a qualified neutral third party to mediate with regard to the disputed portion of the claim. Each Party shall bear the fees and costs charged by its respective mediator in connection with the selection of the neutral mediator.
3.12. 7 .2 For purposes of this section, mediation includes any nonbinding process, including, but not limited to, neutral evaluation or a dispute review board, in which an independent third party or board assists the Parties in dispute resolution through negotiation or by issuance of an evaluation. Any mediation utilized shall conform to the timeframes in this section.
3.12.7.3 Unless otherwise agreed to by City and the Contractor in writing, the mediation conducted pursuant to this section shall excuse any further obligation under Section 20104.4 to mediate after litigation has been commenced.
3.12.7.4 The mediation shall be held no earlier than the date the Contractor completes the Work or the date that the Contractor last performs Work, whichever is earlier. All unresolved Claims shall be considered jointly in a single mediation, unless a new unrelated Claim arises after mediation is completed.
3.12.8 Procedures After Mediation. If following the mediation, the Claim or any portion remains in dispute, the Contractor must file a claim pursuant to Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code. For purposes of those provisions, the running of the period of time within which a claim must be filed shall be tolled from the time the Contractor submits his or her written Claim pursuant to subdivision (a) until the time the Claim is denied, including any period of time utilized by the meet and confer conference or mediation.
3.12.9 Civil Actions. The following procedures are established for all civil actions filed to resolve Claims of $375,000 or less:
3.12.9.1 Within 60 Days, but no earlier than 30 Days, following the filing or responsive pleadings, the court shall submit the matter to non-binding mediation unless waived by mutual stipulation of both Parties or unless mediation was held prior to commencement of the action in accordance with Public Contract Code section 9204 and the terms of these procedures.
The mediation process shall provide for the selection within 15 Days by both Parties of a disinterested third person as mediator, shall be commenced within 30 Days of the submittal, and shall be concluded within 15 Days from the commencement of the mediation unless a time requirement is extended upon a good cause showing to the court.
3.12.9.2 If the matter remains in dispute, the case shall be submitted to judicial arbitration pursuant to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, notwithstanding Section 1114.11 of that code. The Civil Discovery Act of 1986 (Article 3 (commencing with Section 2016) of Chapter 3 of Title 3 of Part 4 of the Code of Civil Procedure) shall apply to any proceeding brought under this subdivision consistent with the rules pertaining to judicial arbitration.
Revised 10.5.21 SHORT FORM CONSTRUCTION CONTRAC
55575 18165\33505817.1
Item 1I - Page 86
3.12.9.3 In addition to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, (A) arbitrators shall, when possible, be experienced in construction law, and (B) any party appealing an arbitration award who does not obtain a more favorable judgment shall, in addition to payment of costs and fees under that chapter, also pay the attorney's fees on appeal of the other party.
3.12.10 Government Code Claim Procedures.
3.12.10.1 This section does not apply to tort claims and nothing in this section is intended nor shall be construed to change the time periods for filing tort claims or actions specified by Chapter 1 (commending with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.5 of Title 1 of the Government Code.
3.12.10.2 In addition to any and all Contract requirements pertaining to notices of and requests for adjustments to the Contract Time, Contract Price, or compensation or payment for extra work, disputed work, claims and/or changed conditions, Contractor must comply with the claim procedures set forth in Government Code sections 900 et seq. prior to filing any lawsuit against the City.
3.12.10.3 Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to adjustment of the Contract Time, Contract Price, or compensation or payment for extra work, disputed work, claims, and/or changed conditions have been followed by Contractor. If no such Government Code claim is submitted, or if any prerequisite contractual requirements are not otherwise satisfied as specified herein, Contractor may not file any action against the City.
3.12.10.4 A Government Code claim must be filed no earlier than the date the work is completed or the date the Contractor last performs work on the Project, whichever occurs first. A Government Code claim shall be inclusive of all unresolved Claims known to the Contractor excepting only new unrelated Claims that arise after the Government Code claim is submitted.
3.12.11 Non-Waiver. City's failure to respond to a Claim from the Contractor within the time periods described in this section or to otherwise meet the time requirements of this section shall result in the Claim being deemed rejected in its entirety and shall not constitute a waiver of any rights under this section.
3.13 Loss and Damage. Except as may otherwise be limited by law, Contractor shall be responsible for all loss and damage which may arise out of the nature of the Work agreed to herein, or from the action of the elements, or from any unforeseen difficulties which may arise or be encountered in the prosecution of the Work until the same is fully completed and accepted by City. In the event of damage proximately caused by an Act of God, as defined by Section 7105 of the Public Contract Code, the City may terminate this Contract pursuant to the termination provisions in this Contract; provided, however, that the City needs to provide Contractor with only one ( 1) day advanced written notice.
3.14 Indemnification.
3.14.1 Scope of Indemnity. To the fullest extent permitted by law, Contractor shall defend, indemnify and hold the City, its officials, employees, agents and volunteers free and Revised 10.5.21
55575.1816fil3SOS817. I
15 SHORT FORM CONSTRUCTION CONTRA°@
Item 1I - Page 87
harmless from any and all claims, demands, causes of action, suits, actions, proceedings, costs, expenses, liability, judgments, awards, decrees, settlements, loss, damage or injury of any kind, in law or equity, regardless of whether the allegations are false, fraudulent, or groundless, to property or persons, including wrongful death, (collectively, "Claims") in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Contractor, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Contractor's services, the Project or this Contract, including without limitation the payment of all expert witness fees, attorneys' fees and other related costs and expenses.
Notwithstanding the foregoing, to the extent required by Civil Code section 2782, Contractor's indemnity obligation shall not apply to such loss or damage which is caused by the sole or active negligence or willful misconduct of the City.
3.14.2 Additional Indemnity Obligations. Contractor shall defend, with counsel of City's choosing and at Contractor's own cost, expense and risk, any and all Claims covered by this section that may be brought or instituted against City or its officials, employees, agents and authorized volunteers. In addition, Contractor shall pay and satisfy any judgment, award or decree that may be rendered against City or its officials, employees, agents and authorized volunteers as part of any such claim, suit, action or other proceeding. Contractor shall also reimburse City for the cost of any settlement paid by City or its officials, employees, agents and authorized volunteers as part of any such claim, suit, action or other proceeding. Such reimbursement shall include payment for City's attorney's fees and costs, including expert witness fees. Contractor shall reimburse City and its officials, employees, agents and authorized volunteers, for any and all legal expenses and costs incurred by each of them in connection therewith or in enforcing the indemnity herein provided. Contractor's obligation to indemnify shall survive expiration or termination of this Contract, and shall not be restricted to insurance proceeds, if any, received by the City, its officials, employees, agents and authorized volunteers.
3.15 Insurance.
3.15.1 Time for Compliance. Contractor shall not commence Work under this Contract until it has provided evidence satisfactory to the City that it has secured all insurance required under this section. In addition, Contractor shall not allow any subcontractor to commence work on any subcontract until it has provided evidence satisfactory to the City that the subcontractor has secured all insurance required under this section. Failure to provide and maintain all required insurance shall be grounds for the City to terminate this Contract for cause.
3.15.2 Minimum Requirements. Contractor shall, at its expense, procure and maintain for the duration of the Contract insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the Work hereunder by Contractor, its agents, representatives, employees or subcontractors. Contractor shall also require all of its subcontractors to procure and maintain the same insurance for the duration of the Contract. Such insurance shall meet at least the following minimum levels of coverage:
3.15.2.1 Minimum Scope of Insurance. Coverage shall be at least as broad as the latest version of the following: (1) General Liability: Insurance Services Office Commercial General Liability coverage (occurrence form CG 00 01) OR Insurance Services Office Owners and Contractors Protective Liability Coverage Form (CG 00 09 11 88) (coverage for operations of designated contractor); (2) Automobile Liability: Insurance Services Office Business Auto Coverage form number CA 00 01, code 1 (any auto); (3) Workers' Compensation and Employer's Liability: Workers' Compensation insurance as required by the State of California and Revised 10.5.21 16 SHORT FORM CONSTRUCTION CONT
55575 18165\33505817. I
Item 1I - Page 88
Employer's Liability Insurance; and (4) Buifders'IA/1 Risk: Builders'/AII Risk insurance covering for all risks of loss, including explosion, collapse, underground excavation and removal of lateral support (and including earthquakes and floods if requested by the City). Policies shall not contain exclusions contrary to this Contract.
3.15.2.2 Minimum Limits of Insurance. Contractor shall maintain limits no less than: (1) General Liability: $2,000,000 per occurrence and $4,000,000 general aggregate for bodily injury, personal injury and property damage; (2) Automobile Liability: $1,000,000 per accident for bodily injury and property damage; (3) Workers' Compensation and Employer's Liability: Workers' compensation limits as required by the Labor Code of the State of California.
Employer's Liability limits of $1,000,000 each accident, policy limit bodily injury or disease, and each employee bodily injury or disease; and (4) Builders'IAII Risk: Completed value of the project.
Defense costs shall be available in addition to the limits. Notwithstanding the minimum limits specified herein, any available coverage shall be provided to the parties required to be named as additional insureds pursuant to this Contract.
3.15.2.3 Notices: Cancellation or Reduction of Coverage. At least fifteen (15) days prior to the expiration of any such policy, evidence showing that such insurance coverage has been renewed or extended shall be filed with the City. If such coverage is cancelled or materially reduced, Contractor shall, within ten (10) days after receipt of written notice of such cancellation or reduction of coverage, file with the City evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies. In the event any policy of insurance required under this Contract does not comply with these specifications or is canceled and not replaced, the City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by the City will be promptly reimbursed by Contractor or the City may withhold amounts sufficient to pay premium from Contractor payments. In the alternative, the City may suspend or terminate this Contract.
3.15.3 Insurance Endorsements. The insurance policies shall contain the following provisions, or Contractor shall provide endorsements (amendments) on forms supplied or approved by the City to add the following provisions to the insurance policies:
3.15.3.1 General Liability. (1) Such policy shall give the City, its officials, employees, agents and volunteers additional insured status using ISO endorsements CG20 10 1 O 01 plus CG20 37 1 O 01, or endorsements providing the exact same coverage, with respect to the Work or operations performed by or on behalf of Contractor, including materials, parts or equipment furnished in connection with such work; (2) all policies shall waive or shall permit Contractor to waive all rights of subrogation which may be obtained by the Contractor or any insurer by virtue of payment of any loss or any coverage provided to any person named as an additional insured pursuant to this Contract, and Contractor agrees to waive all such rights of subrogation; and (3) the insurance coverage shall be primary insurance as respects the City, its officials, employees, agents and volunteers, or if excess, shall stand in an unbroken chain of coverage excess of Contractor's scheduled underlying coverage. Any insurance or self-insurance maintained by the City, its officials, employees, agents and volunteers shall be excess of Contractor's insurance and shall not be called upon to contribute with it.
3.15.3.2 Automobile Liability. (1) Such policy shall give the City, its officials, employees, agents and volunteers additional insured status with respect to the ownership, operation, maintenance, use, loading or unloading of any auto owned, leased, hired or borrowed by Contractor or for which Contractor is responsible; (2) all policies shall waive or shall permit Contractor to waive all rights of subrogation which may be obtained by the Contractor Revised 10.5.21
55575.18165\335058 I 7. I
17 SHORT FORM CONSTRUCTION CON'ID
Item 1I - Page 89
or any insurer by virtue of payment of any loss or any coverage provided to any person named as an additional insured pursuant to this Contract, and Contractor agrees to waive all such rights of subrogation; and (3) the insurance coverage shall be primary insurance as respects the City, its officials, employees, agents and volunteers, or if excess, shall stand in an unbroken chain of coverage excess of Contractor's scheduled underlying coverage. Any insurance or self-insurance maintained by the City, its officials, employees, agents and volunteers shall be excess of Contractor's insurance and shall not be called upon to contribute with it in any way.
3.15.3.3 Workers' Compensation and Employer's Liability Coverage.
The insurer shall agree to waive all rights of subrogation against the City, its officials, employees, agents and volunteers for losses paid under the terms of the insurance policy which arise from work performed by Contractor.
3.15.3.4 All Coverages. Each insurance policy required by this Contract shall be endorsed to state that: (1) coverage shall not be suspended, voided, reduced or canceled except after thirty (30) days prior written notice by certified mail, return receipt requested, has been given to the City; and (2) any failure to comply with reporting or other provisions of the policies, including breaches of warranties, shall not affect coverage provided to the City, its officials, employees, agents and volunteers.
3.15.4 Builders'/AII Risk Policy Requirements. The builders'/all risk insurance shall provide that the City be named as loss payee. In addition, the insurer shall waive all rights of subrogation against the City.
3.15.5 Separation of Insureds: No Special Limitations. All insurance required by this Section shall contain standard separation of insureds provisions. In addition, such insurance shall not contain any special limitations on the scope of protection afforded to the City, its officials, employees, agents and volunteers.
3.15.6 Professional Liability Insurance. All architects, engineers, consultants or design professionals retained by Contractor shall also procure and maintain, for a period of five (5) years following completion of the Contract. errors and omissions liability insurance with a limit of not less than $1,000,000 per occurrence. This insurance shall name the City, its directors, officials, officers, employees, agents and volunteers as additional and insureds with respect to Work performed, and shall otherwise comply with all requirements of this Section. Defense costs shall be paid in addition to the limits.
3.15. 7 Deductibles and Self-Insurance Retentions. Any deductibles or self- insured retentions must be declared to and approved by the City. Contractor shall guarantee that, at the option of the City, either: (1) the insurer shall reduce or eliminate such deductibles or self insured retentions as respects the City, its officials, employees, agents and authorized volunteers; or (2) the Contractor shall procure a bond or other financial guarantee acceptable to the City guaranteeing payment of losses and related investigation costs, claims and administrative and defense expenses.
3.15.8 Acceptability of Insurers. Insurance is to be placed with insurers with a current A.M. Best's rating no less than A:VII, licensed to do business in California, and satisfactory to the City. Exception may be made for the State Compensation Insurance Fund when not specifically rated.
Revised 10.5.21
55575.18165\33505817.1
18 SHORT FORM CONSTRUCTION CONTRA~
Item 1I - Page 90
3.15.9 Verification of Coverage. Contractor shall furnish City with original certificates of insurance and endorsements effecting coverage required by this Contract on forms satisfactory to the City. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf, and shall be on forms supplied or approved by the City. All certificates and endorsements must be received and approved by the City before work commences. The City reserves the right to require complete, certified copies of all required insurance policies, at any time.
3.15.10 Subcontractors. All subcontractors shall meet the requirements of this Section before commencing Work. Contractor shall furnish separate certificates and endorsements for each subcontractor. Subcontractor policies of General Liability insurance shall name the City, its officials, employees, agents and authorized volunteers as additional insureds using form ISO 20 38 04 13 or endorsements providing the exact same coverage. All coverages for subcontractors shall be subject to all of the requirements stated herein except as otherwise agreed to by the City in writing.
3.15.11 Reporting of Claims. Contractor shall report to the City, in addition to Contractor's insurer, any and all insurance claims submitted by Contractor in connection with the Work under this Contract.
3.16 Bond Requirements.
3.16.1 Payment Bond. If required by law or otherwise specifically requested by City in Exhibit "C" attached hereto and incorporated herein by reference, Contractor shall execute and provide to City concurrently with this Contract a Payment Bond in an amount required by the City and in a form provided or approved by the City. If such bond is required, no payment will be made to Contractor until the bond has been received and approved by the City.
3.16.2 Performance Bond. If specifically requested by City in Exhibit "C" attached hereto and incorporated herein by reference, Contractor shall execute and provide to City concurrently with this Contract a Performance Bond in an amount required by the City and in a form provided or approved by the City. If such bond is required, no payment will be made to Contractor until the bond has been received and approved by the City.
3.16.3 Bond Provisions. Should, in City's sole opinion, any bond become insufficient or any surety be found to be unsatisfactory, Contractor shall renew or replace the effected bond within (ten) 10 days of receiving notice from City. In the event the surety or Contractor intends to reduce or cancel any required bond, at least thirty (30) days prior written notice shall be given to the City, and Contractor shall post acceptable replacement bonds at least ten (1 O) days prior to expiration of the original bonds. No further payments shall be deemed due or will be made under this Contract until any replacement bonds required by this Section are accepted by the City. To the extent, if any, that the Total Contract Price is increased in accordance with the Contract, Contractor shall, upon request of the City, cause the amount of the bond to be increased accordingly and shall promptly deliver satisfactory evidence of such increase to the City. If Contractor fails to furnish any required bond, the City may terminate the Contract for cause.
3.16.4 Surety Qualifications. Only bonds executed by an admitted surety insurer, as defined in California Code of Civil Procedure Section 995.120, shall be accepted. If a Revised 10.5.21
5557518165\33505817.I
19 SHORT FORM CONSTRUCTION CONTRAC~
Item 1I - Page 91
California-admitted surety insurer issuing bonds does not meet these requirements, the insurer will be considered qualified if it is in conformance with Section 995.660 of the California Code of Civil Procedure, and proof of such is provided to the City.
3.17 Warranty. Contractor warrants all Work under the Contract (which for purposes of this Section shall be deemed to include unauthorized work which has not been removed and any non-conforming materials incorporated into the Work) to be of good quality and free from any defective or faulty material and workmanship. Contractor agrees that for a period of one year (or the period of time specified elsewhere in the Contract or in any guarantee or warranty provided by any manufacturer or supplier of equipment or materials incorporated into the Work, whichever is later) after the date of final acceptance, Contractor shall within ten (10) days after being notified in writing by the City of any defect in the Work or non-conformance of the Work to the Contract, commence and prosecute with due diligence all Work necessary to fulfill the terms of the warranty at its sole cost and expense. Contractor shall act sooner as requested by the City in response to an emergency. In addition, Contractor shall, at its sole cost and expense, repair and replace any portions of the Work (or work of other contractors) damaged by its defective Work or which becomes damaged in the course of repairing or replacing defective Work. For any Work so corrected, Contractor's obligation hereunder to correct defective Work shall be reinstated for an additional one year period, commencing with the date of acceptance of such corrected Work.
Contractor shall perform such tests as the City may require to verify that any corrective actions, including, without limitation, redesign, repairs, and replacements comply with the requirements of the Contract. All costs associated with such corrective actions and testing, including the removal, replacement, and reinstitution of equipment and materials necessary to gain access, shall be the sole responsibility of Contractor. All warranties and guarantees of subcontractors, suppliers and manufacturers with respect to any portion of the Work, whether express or implied, are deemed to be obtained by Contractor for the benefit of the City, regardless of whether or not such warranties and guarantees have been transferred or assigned to the City by separate agreement and Contractor agrees to enforce such warranties and guarantees, if necessary, on behalf of the City. In the event that Contractor fails to perform its obligations under this Section, or under any other warranty or guaranty under this Contract, to the reasonable satisfaction of the City, the City shall have the right to correct and replace any defective or non-conforming Work and any work damaged by such work or the replacement or correction thereof at Contractor's sole expense.
Contractor shall be obligated to fully reimburse the City for any expenses incurred hereunder upon demand.
3.18 Employee/Labor Certifications.
3.18.1 Contractor's Labor Certification. By its signature hereunder, Contractor certifies that he is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker's Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Work. A certification form for this purpose, which is attached to this Contract as Exhibit "D" and incorporated herein by reference, shall be executed simultaneously with this Contract.
3.18.2 Equal Opportunity Employment. Contractor represents that it is an equal opportunity employer and that it shall not discriminate against any employee or applicant for employment because of race, religion, color, national origin, ancestry, sex, age or other interests protected by the State or Federal Constitutions. Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination.
Revised 10.5.21
55575. I 8 I 65\3350S8I7 I
20 SHORT FORM CONSTRUCTION CONTRAC9
Item 1I - Page 92
3.18.3 Verification of Employment Eligibility. By executing this Contract, Contractor verifies that it fully complies with all requirements and restrictions of state and federal law respecting the employment of undocumented aliens, including, but not limited to, the Immigration Reform and Control Act of 1986, as may be amended from time to time, and shall require all subcontractors and sub-subcontractors to comply with the same.
3.19 Termination. This Contract may be terminated by City at any time, either with our without cause, by giving Contractor three (3) days advance written notice. In the event of termination by City for any reason other than the fault of Contractor, City shall pay Contractor for all Work performed up to that time as provided herein. In the event of breach of the Contract by Contractor, City may terminate the Contract immediately without notice, may reduce payment to Contractor in the amount necessary to offset City's resulting damages, and may pursue any other available recourse against Contractor. Contractor may not terminate this Contract except for cause. In the event this Contract is terminated in whole or in part as provided, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated. Further, if this Contract is terminated as provided, City may require Contractor to provide all finished or unfinished documents, data, diagrams, drawings, materials or other matter prepared or built by Contractor in connection with its performance of this Contract. Contractor shall be required to provide such document and other information within fifteen (15) days of the request.
3.20 City Officers and Employees: Non-Discrimination.
3.20.1 Non-liability of City Officers and Employees. No officer or employee of the City shall be personally liable to the Contractor, or any successor-in-interest, in the event of any default or breach by the City or for any amount which may become due to the Contractor or to its successor, or for breach of any obligation of the terms of this Contract.
3.20.2 Conflict of Interest. Contractor acknowledges that no officer or employee of the City has or shall have any direct or indirect financial interest in this Contract nor shall Contractor enter into any agreement of any kind with any such officer or employee during the term of this Contract and for one (1) year thereafter. Contractor warrants that Contractor has not paid or given, and will not pay or give, any third party any money or other consideration in exchange for obtaining this Contract.
3.20.3 Covenant Against Discrimination. In connection with its performance under this Contract, Contractor shall not discriminate against any employee or applicant for employment because of actual or perceived race, religion, color, sex, age, marital status, ancestry, national origin ( i.e., place of origin, immigration status, cultural or linguistic characteristics, or ethnicity), sexual orientation, gender identity, gender expression, physical or mental disability, or medical condition (each a "prohibited basis"). Contractor shall ensure that applicants are employed, and that employees are treated during their employment, without regard to any prohibited basis. As a condition precedent to City's lawful capacity to enter this Contract, and in executing this Contract, Contractor certifies that its actions and omissions hereunder shall not incorporate any discrimination arising from or related to any prohibited basis in any Contractor activity, including but not limited to the following: employment, upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship; and further, that Contractor is in full compliance with the provisions of Palm Springs Municipal Code Section 7.09.040, including without limitation the provision of benefits, relating to non-discrimination in city contracting.
Revised 10.5.21
55575.18165\335058 I 7 I
21 SHORT FORM CONSTRUCTIO CT
Item 1I - Page 93
3.21 General Provisions.
3.21.1 City's Representative. The City hereby designates the City Manager, or his or her designee, to act as its representative for the performance of this Contract ("City's Representative"). City's Representative shall have the power to act on behalf of the City for all purposes under this Contract. Contractor shall not accept direction or orders from any person other than the City's Representative or his or her designee.
3.21.2 Contractor's Representative. Before starting the Work, Contractor shall submit in writing the name, qualifications and experience of its proposed representative who shall be subject to the review and approval of the City ('"Contractor's Representative"). Following approval by the City, Contractor's Representative shall have full authority to represent and act on behalf of Contractor for all purposes under this Contract. Contractor's Representative shall supervise and direct the Work, using his best skill and attention, and shall be responsible for all construction means, methods, techniques, sequences and procedures and for the satisfactory coordination of all portions of the Work under this Contract. Contractor's Representative shall devote full time to the Project and either he or his designee, who shall be acceptable to the City, shall be present at the Work site at all times that any Work is in progress and at any time that any employee or subcontractor of Contractor is present at the Work site. Arrangements for responsible supervision, acceptable to the City, shall be made for emergency Work which may be required. Should Contractor desire to change its Contractor's Representative, Contractor shall provide the information specified above and obtain the City's written approval.
3.21.3 Contract Interpretation. Should any question arise regarding the meaning or import of any of the provisions of this Contract or written or oral instructions from City, the matter shall be referred to City's Representative, whose decision shall be binding upon Contractor.
3.21.4 Anti-Trust Claims. This provision shall be operative if this Contract is applicable to California Public Contract Code Section 7103.5. In entering into this Contract to supply goods, services or materials, Contractor hereby offers and agrees to assign to the City all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Section 15) or under the Cartwright Act (Chapter 2, commencing with Section 16700, of Part 2 of Division 7 of the Business and Professions Code) arising from purchases of goods, services, or materials pursuant to the Contract. This assignment shall be made and become effective at the time the City tender final payment to Contractor, without further acknowledgment by the Parties.
3.21.5 Notices. All notices hereunder and communications regarding interpretation of the terms of the Contract or changes thereto shall be provided by the mailing thereof by registered or certified mail, return receipt requested, postage prepaid and addressed as follows:
CONTRACTOR:
Revised 10.5.21
55575.I8I65\335058 l 7 I
MIRACLE RECREATION EQUIPMENT COMPANY
878 HIGHWAY 60
MONETT, MO 65708
ATTN: KEVIN WALKER
22 Item 1I - Page 94
CITY:
CITY OF PALM SPRINGS
3200 E. TAHOUITZ CANYON WAY
PALM SPRINGS, CA 92262
ATTN: CITY MANAGER & CITY CLERK
Any notice so given shall be considered received by the other Party three (3) days after deposit in the U.S. Mail as stated above and addressed to the Party at the above address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.
3.21.6 Time of Essence. Time is of the essence in the performance of this Contract.
3.21.7 Assignment Forbidden. Contractor shall not, either voluntarily or by action of law, assign or transfer this Contract or any obligation, right, title or interest assumed by Contractor herein without the prior written consent of City. If Contractor attempts an assignment or transfer of this Contract or any obligation, right, title or interest herein, City may, at its option, terminate and revoke the Contract and shall thereupon be relieved from any and all obligations to Contractor or its assignee or transferee.
3.21.8 No Third Party Beneficiaries. There are no intended third party beneficiaries of any right or obligation assumed by the Parties.
3.21.9 Laws: Venue. This Contract shall be interpreted in accordance with the laws of the State of California. If any action is brought to interpret or enforce any term of this Contract, the action shall be brought in a state or federal court situated in the County of Riverside, State of California.
3.21.1 0 Attorneys' Fees. If either Party commences an action against the other party, either legal, administrative or otherwise, arising out of or in connection with this Contract, the prevailing party in such litigation shall be entitled to have and recover from the losing party reasonable attorneys' fees and all other costs of such action.
3.21.11 Counterparts. This Contract may be executed in counterparts, each of which shall constitute an original.
3.21.12 Successors. The Parties do for themselves, their heirs, executors, administrators, successors, and assigns agree to the full performance of all of the provisions contained in this Contract.
3.21.13 Solicitation. Contractor maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Contractor, to solicit or secure this Contract. Further, Contractor warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Contractor, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Contract. For breach or violation of this warranty, City shall have the right to terminate this Contract without liability.
3.21.14 Certification of License.
Revised 10.5.21
55575, 18165\33~5817. I
23 SHORT FORM CONSTRUCTION CONW
Item 1I - Page 95
3.21.14.1 Contractor certifies that as of the date of execution of this Contract, Contractor has a current contractor's license of the classification indicated below under Contractor's signature.
3.21.14.2 Contractors are required by law to be licensed and regulated by the Contractors' State License Board which has jurisdiction to investigate complaints against contractors if a complaint regarding a patent act or omission is filed within four (4) years of the date of the alleged violation. A complaint regarding a latent act or omission pertaining to structural defects must be filed within ten (10) years of the date of the alleged violation. Any questions concerning a contractor may be referred to the Registrar, Contractors' State License Board, P.O.
Box 26000, Sacramento, California 95826.
3.21.15 Authority to Enter Contract. Each Party warrants that the individuals who have signed this Contract have the legal power, right and authority to make this Contract and bind each respective Party.
3.21.16 Entire Contract: Modification. This Contract contains the entire agreement of the Parties with respect to the subject matter hereof, and supersedes all prior negotiations, understandings or agreements. This Contract may only be modified by a writing signed by both Parties.
3.21 .17 Non-Waiver. None of the provisions of this Contract shall be considered waived by either party, unless such waiver is specifically specified in writing.
3.21.18 City's Right to Employ Other Contractors. City reserves right to employ other contractors in connection with this Project or other projects.
3.22 Compliance with Economic Sanctions in Response to Russia's Actions in Ukraine. When funding for the services is provided, in whole or in part, by an agency controlled of the State of California, Consultant shall fully and adequately comply with California Executive Order N-6-22 ("Russian Sanctions Program"). As part of this compliance process, Consultant shall also certify compliance with the Russian Sanctions Program by completing the form located in Attachment "G" (Russian Sanctions Certification), attached hereto and incorporated herein by reference. Consultant shall also require any subconsultants to comply with the Russian Sanctions Program and certify compliance pursuant to this Section.
Revised 10.5.21
55575.18165\33505817.1
[Signatures on Next Page]
24 Item 1I - Page 96
SIGNATURE PAGE TO AGREEMENT BY AND BETWEEN THE CITY OF PALM
SPRINGS AND MIRACLE RECREATION EQUIPMENT COMPANY
IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below.
Date: _f {)/_lf ........ (_Vi __ _
(
CITY OF PALM SPRINGS:
APPROVED BY CITY COUNCIL:
Date: N/A Item No. N/A
APPROVED AS TO FORM:
By:-----------
City Attorney
APPROVED:
By:_s_~-g~a~~~re~~-~~-·-· ----
(2nd signature required for Corporations)
Date: _f__,Q/ ___ 1r_l __ i_o_zl ____ _
'/
ATTEST:
By ____________ _
City Clerk
By:_____________ Date: _________ _
Lauri Aylaian, Interim Director of Parks & Recreation
By:_____________ Date: _________ _
City Manager -over $50,000
Deputy/Assistant City Manager -up to $50,000
Director -up to $25,000
Manager -up to $5,000
Revised 10.5.21
5.5.S7518165\33505817.I
25 SHORT FORM CONSTRUCTION CONTRACT
Item 1I - Page 97
EXHIBIT "A"
SERVICES/ SCHEDULE
Scope of services shall include the purchase and installation of rubber surfacing at Desert Highland Park exercise equipment as identified in Exhibit B, in accordance with the Cooperative Purchase Pricing identified by Sourcewell Contract #010521-L TS.
Revised 10.5.21
55575.18165\335058 I 7, I
Exhibit A· 1 SHORT FORM CONSTRUCTION CONTRA@
Item 1I - Page 98
EXHIBIT "B"
SCHEDULE OF COMPENSATION
P;.yment Addnlss
Miracle MirHe Re<nation EquiprMnt Ccmpany
PO Box 734154
Dabs lX 75373-4154
Phone # (800) 264-7226
Fu#(877)21~380Q
[email protected]
-.rriracl.,_,...._com
c ... tiamer I City d Palm Springs
,._
Tabitha RiClhards
PIion. I (7GO) 323-8202
Em,11 tabitha.ridlardsCp,almspringsca.gcw
1:~ 1~~-----IPa,ymentTenns Net30
,---................ ..,, ...... _, ....... ......,
lll!rn#&DHc:riplion
MOBILIZATION
MOBILIZE EQUIPMENT AND MATERIALS
SITE PREPARATION
EXCAVATION AND DlSPOSE OF EXISTING TURF/SOIL.
APPROXIMATELY 1,750 SQFT.
SITE PREPARATION
CONSTRUCTION OF CONCRETE CURB FOR EACH
FITNESS STATION, APPROXIMATELY 553 LINEAR FEET
IN TOTAL. 6" WIDTH lC 6" DEPTH.
SITE PREPARATION
PROVIDE, GRADE ANOCOMPACTSUB BASE
MATERIALS. APPROXIMATELY 1,750 SOFT
Revised 10.5.21 Exhibit B -1
55575. 18165\33505817 I
Estlmalll! Number
Estimate o.te
Expiration Data
Qwntily
MREC7144
00--30-2024
10-30-2024
Total
1 $4,025.00
2 $6,540.00
6 $26,706.00
1 $5,051.00
Item 1I - Page 99
POURED IN PLACE RUBBER SURFACING
PROVIDE AND INSTALL POUR IN PLACE RUBBER
SURFACING. 50/50 BLACK ANDSTANDARDCOLOR
WITH AROMATIC BINDER. EXCLUDES DESIGNS AND
GRAPHICS. APPROXIMATELY 1,750 SQFT. FOR AN AVG.
CFHOF 8'
Bond Fee
Per Souroewell Contract li()10521-LTS-3
I Grand Total I $79,662.00
NOTES ANO EXCLUSIONS:
This estimate shall not become binding unlit signed and returned for approval.
A signatUTe indicates acceptance d all terms. conditions, .ind prices Usted. 1 $35,000.00
1 $2,340.00
$79,662.00
Sales Tax $0.00
Product Total $79,662.00
A signed quole will not substitute for a Purchase O'der if one i5 requited by 1he CuslOfflel'. Make purchue Ofders out to MiRW Rec;rution
Exdusians: All Unloading, Stor,31ge, Installation, Site Wort. Fees & Permits, outside of the quoted above.
Footing calculations ror playground equipment can be added for an adcitional fee if required All signed quotes Mid/or purchase order.; should be emai'led to [email protected] or faxed to 877~215- 3869. Hard copies can be mailed to Miracle Playgrou,id Sales 1101 California Ave Suite 209 Coro11a, CA 92881 THIS QUOTE IS LIMITED TO AHO GOVERNED BY TliE TERMS OONTAINl:D HERflN. ltrade Dlljml IICI any DIiier ll!ffllli pltlpDlecl Dy me CIIIUlmer JI i.11'.l'lg or Glh.wlie. • matnal ar.tra110111, anel al wefl llllmli •llaJ lie valel. 111110111tomer aut1011Ze1 Mlraae 1D 51\!p tne equipment anCI pay Mlracle Ille tDtilt amount spteffll!d. Sll.,~g 18l'M are FOB Ille pl,Xe or ~m 'Ila a ccmman ca111Kdflllgnatedlly Mlrxle. TIie ClatomK agJ'eK to Pill' iii ilClcllllotlil 14!rvll:e CltargK !Ur pHt Clue lmllltllH per 1111! tams lllled al>IJ;e. TM ailllClmer miat pruvldl! p111per tu exemp:JDn ca11Scate1 !D Mtraae and pnmpUy pay anel dliellilige l!I applca~ taxe5. ~ 1-1. ll'IIK. and o:.mia other lmpoilllGN en Ille equpnentat b IGCe l!JP"IM.
Revised 10.5.21
55575.18165\33505817. I
Exhibit 8 • 2 SHORT FORM CONSTRUCTION CONTR~
Item 1I - Page 100
EXHIBIT "C"
ARTICLE 1. BONDS
Concurrently with this Contract, the Contractor shall deliver to the City four identical counterparts of the Performance Bond and Payment Bond on the forms supplied by the City and included as Exhibit "F" to the Contract. The surety supplying the bond must be an admitted surety insurer, as defined in Code of Civil Procedure Section 995.120, authorized to do business as such in the State of California and satisfactory to the City. The Performance Bond and the Payment Bond shall be for one hundred percent (100%) of the Total Contract Price.
Revised 10.5.21
55515 18165\33505817 I
Exhibit C -1 SHORT FORM CONSTRUCTION CON~
Item 1I - Page 101
EXHIBIT "D"
CERTIFICATION
LABOR CODE -SECTION 1861
I, the undersigned Contractor, am aware of the provisions of Section 3700, et seq., of the California Labor Code which require every employer to be insured against liability for Worker's Compensation or to undertake self-insurance in accordance with the provisions of the Code, and I, the undersigned Contractor, agree to and will comply with such provisions before commencing the performance of the Work on this Contract.
MIRACLE RECREATION EQUIPMENT COMPANY
By:
Signature
Name (PrinQ
Title (Print)
Revised 10.5.21
55575.18165\335058l7 I
Exhibit D • 1 SHORT FORM CONSTRUCTION CONTRACT
Item 1I - Page 102
EXHIBIT "E"
PUBLIC WORKS CONTRACTOR REGISTRATION CERTIFICATION
Pursuant to Labor Code sections 1725.5 and 1771.1, all contractors and subcontractors that wish to bid on, be listed in a bid proposal, or enter into a contract to perform public work must be registered with the Department of Industrial Relations. See http://www.dir.ca.gov/Public Works/PublicWorks.html for additional information.
No bid will be accepted nor any contract entered into without proof of the contractor's and subcontractors' current registration with the Department of Industrial Relations to perform public work.
Contractor hereby certifies that it is aware of the registration requirements set forth in Labor Code sections 1725.5 and 1771.1 and is currently registered as a contractor with the Department of Industrial Relations. 1
Name of Contractor: Miracle Recreation Equipment Inc
D1 R Registration Number:"""1..aa.0=00:;..;:0;..;:;3=39=3=2..__ _____ _ DIR Registration Expiration: .... 9/_3_1_/2_0_2_5 ______ _ Small Project Exemption: __ Yes or _X_ No
Unless Contractor is exempt pursuant to the small project exemption, Contractor further acknowledges:
1. Contractor shall maintain a current DIR registration for the duration of the project.
2. Contractor shall include the requirements of Labor Code sections 1725.5 and 1771.1 in its contract with subcontractors and ensure that all subcontractors are registered at the time of bid opening and maintain registration status for the duration of the project.
3. Failure to submit this form or comply with any of the above requirements may result in a finding that the bid is non-responsive.
Name of Cont<#tor/JILJ. &,_ ,4
Signature: 1J--~
Name and Title: ~tUv) WJk cJ M,~
Dated:__....f-@,..l ...,b ...... t .... i ..... ~....,_ ____ _ , 1 If the Project is exempt from the contractor registration requirements pursuant to the small project exemption under Labor Code Sections 1725.5 and 1771.1, please mark "Yes" in response to "Small Project Exemption." Revised 10.5.21
55575.18165\33505817 I
Exhibit E -1 SHORT FORM CONSTRUCTION CONTRACT
Item 1I - Page 103
Revised 4.13.23
55575.18165\33505817.1
EXHIBIT "F"
PAYMENT AND PERFORMANCE BONDS
Exhibit F • 1 SHORT FORM CONSTRUCTION CONTRACT (P
Item 1I - Page 104
EXHIBIT "G"
EXECUTIVE ORDER N-6-22 CERTIFICATION
Executive Order N-6-22 issued by Governor Gavin Newsom on March 4, 2022, directs all agencies and departments that are subject to the Governor's authority to (a) terminate any contracts with any individuals or entities that are determined to be a target of economic sanctions against Russia and Russian entities and individuals; and (b) refrain from entering into any new contracts with such individuals or entities while the aforementioned sanctions are in effect.
Executive Order N-6-22 also requires that any contractor that: (1) currently has a contract with the City of Palm Springs funded through grant funds provided by the State of California; and/or (2) submits a bid or proposal or otherwise proposes to or enter into or renew a contract with the City of Palm Springs with State of California grant funds, certify that the person is not the target of any economic sanctions against Russia and Russian entities and individuals.
The contractor hereby certifies, SUBJECT TO PENAL TY FOR PERJURY, that a) the contractor is not a target of any economic sanctions against Russian and Russian entities and individuals as discussed in Executive Order N-6-22 and b) the person signing below is duly authorized to legally bind the Contr ctor. This certification is made under the laws of the State of California.
Signature:-"~-;.._ ____________ _
Printed Name: Kev,(/\ Uevl~
Title: CJ Ak.1::¥,
Firm Name: J/t-tcJt.E.,_y1.,tia,. £7'17-{
Date: {D t l~{ i,t.{
Revised 10.5.21 Exhibit G -1 SHORT FORM CONSTRUCTION CONTRACT 55S7S. I 816S\33505817.1
ATTACHMENT G
Item 1I - Page 105
CONTRACT ABSTRACT
Contract/Amendment
Name of Contract:
Company Name:
Company Contact:
Email:
Summary of Services:
Contract Price:
Contract Term:
Public Integrity/ Business
Disclosure Forms:
Contract Administration
Lead Department:
Contract Administrator/ Ext:
Contract Approvals
Council/City Manager Approval Date:
Agreement Number:
Amendment Number:
Contract Compliance
Exhibits:
Insurance:
Routed By:
Bonds:
Business License:
Sole Source Co-Op
CoOp Agmt #: Sole Source
Documents: CoOp Name:
CoOp Pricing:
By: Submitted on:
Contract Abstract Form Rev 8.16.23
Authorized Signers:
Name, Email
(Corporations require 2 signatures)
DESERT HIGHLAND PARK SURFACING IMPROVEMENTS
Miracle Recreation Equipment Company
Bryce Lawrence
[email protected]
CCO adding repairs and replacement of rubberized surfacing at Desert Highland Park
$79,662 + $5,000 = $84,662 revised amount
50 Working Days (no change on CCO#1)
On File
Kevin Walker, [email protected]
Parks & Recreation
Nicholas Gonzalez, Director / X8277
24C253
1 Yes
Yes
Yes
Department
-
No
2/18/25
Janet Burns, Administrative Specialist
Docusign Envelope ID: 009EEB9E-9A25-4119-B1BC-83735A5778C4 Item 1I - Page 106