ATTACHMENT C
Agreement A9145
55575.00001\40098778.2
Revised 2.9.22 Page 1 of 17
CONTRACT SERVICES AGREEMENT A9145
SYSTEMWIDE FLOORING AND INSTALLATION SERVICES
OMNIA PARTNERS CONTRACT 2020002149
THIS AGREEMENT FOR CONTRACT SERVICES (“Agreement”) is made and entered into on June 15, 2022, by and between the City of Palm Springs, a Cal ifornia charter city and municipal corporation (“City”), and Mohawk Commercial, Inc. , a Delaware corporation (“Contractor”). City and Contractor are individually referred to as “Party” and are collectively referred to as the “Parties”.
RECITALS
A. City requires the services of a licensed and qualified flooring contractor , for the purchase and installation of flooring, (“Project”).
B. Contractor is under a cooperative contract through Omnia Partners Contract 2020002149 to provide systemwide flooring to public entities including the City under the terms of this Agreement.
C. Based on its experience , education, training, and reputation, Contractor is qualified and desires to provide the necessary services to City for the Project.
D. City desires to retain the services of Contractor for the Project.
NOW, THEREFORE, in consideration of the promises and mutual obligations, covenants, and conditions contained herein, and other valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties agree as follows:
AGREEMENT
1. CONTRACTOR SERVICES
1.1 Scope of Services . In compliance with all terms and conditions of this Agreement, Contractor shall provide services to City as described in the Scope of Services/Work attached to this Agreement as Exhibit “A” and incorporated herein by reference (the “ Services” or “Work”). Exhibit "A" includes the agreed upon schedule of fees. Contractor warrants that the Services shall be performed in a competent, , and satisfactory manner consistent with the level of care and skill ordinarily exercised by experienced, flooring installers currently practicing under similar conditions in a similar geographic area . In the event of any inconsistency between the terms contained in the Scope of Serv ices/Work and the terms set forth in this Agreement, the terms set forth in this Agreement shall govern.
1.2 Compliance with Law . Contractor shall comply with all applicable federal, state, and local laws, statutes and ordinances and all lawful orders, rules, and regula tions when performing the Services. Contractor shall be liable for all violations of such laws and regulations in connection with the Services and this Agreement.
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 2 of 17
1.3 Licenses and Permits . Contractor shall obtain at its sole cost and exp ense such licenses, permits, and approvals as may be required by law for the performance of the Services required by this Agreement.
1.4 Familiarity with Work . By executing this Agreement, Contractor warrants that it has carefully considered how the Work should be perform ed and fully understands the facilities, difficulties, and restrictions attending performance of the Work under this Agreement.
2. TIME FOR COMPLETION
The time for completion of the Services to be performed by Contractor is an essential condition of this Agreement. Contractor shall prosecute regularly and diligently the work of this Agreement. Neither Party shall be accountable for delays in performance caused by any condition beyond the reasonable control and without the fault or neglige nce of the non - performing Party. Delays shall not entitle Contractor to any additional compensation regardless of the Party responsible for the delay.
3. COMPENSATION OF CONTRACTOR
3.1 Compensation of Contractor. Contractor shall be compensated and reimb ursed for the services rendered under this Agreement in accordance with the schedule of fees set forth in Exhibit “A”. The total amount of Compensation shall not exceed $75,000.
3.2 Method of Payment . In any month in which Contractor wishes to r eceive payment, Contractor shall submit to City an invoice for Services rendered prior to the date of the invoice, no later than the first working day of such month , in the form approved by City’s finance director. Goods ordered shall be invoiced by Contr actor when shipped. Payments shall be based on the rates set forth in Exhibit “A”. City shall pay Contractor for all expenses stated in the invoice that are approved by City and consistent with this Agreement, within thirty (30) days of receipt of Contractor’s invoice.
3.3 Changes. In the event any change or changes in the Services is requested by City, Parties shall execute a written amendment to this Agreement, specifying all proposed amendments, including, but not limited to, any additional fees. An amendment may be entered into:
A. To provide for revisions or modifications to documents , work product, or Work, when required by the enactment or revision of any subsequent law; or B. To provide for additional services not included in this Agreement or n ot customarily furnished in accordance with generally accepted practice in Contractor’s profession.
3.4 Appropriations. This Agreement is subject to, and contingent upon, funds being appropriated by the City Council of City for each fiscal year . If such appropriations are not made, this Agreement shall automatically terminate without penalty to City.
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 3 of 17
4. PERFORMANCE SCHEDULE
4.1 Time of Essence. Time is of the essence in the performance of this Agreement.
4.2 Schedule of Performance. All Services rendered under this Agreement shall be performed under the agreed upon schedule of rates set forth in Exhibit “A .” Any time period extension must be approved in writing by the Contract Officer.
4.3 Force Majeure. The time for performance of Services to be rendered under this Agreement may be extended because of any delays due to a Force Majeure Event if Contractor notifies the Contract Officer within ten (10) days of the commencement of the Force Majeure Event. A Force Majeure Event shall mean an event that m aterially affects the Contra ctor’s performance and is one or more of the following: (1) Acts of God or other natural disasters occurring at the project site; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the Work); and (4) pandemics, epidemics or quarantine restrictions . For purposes of this section, “orders of governmental authorities,” i ncludes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of the City in its capacity as a municipal authority. After Contractor notification, the Contract Officer shall investigate the facts and the extent of any necessary delay and extend the time for performing the Services for the period of the enforced delay when and if , in the Contract Officer’s judgment, such delay is justified. The Contract Officer’s determination shall be fin al and conclusive upon the Parties to this Agreement. The Contractor will not receive an adjustment to the contract price or any other compensation. Notwithstanding the foregoing, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement.
4.4 Term. Unless earlier terminated in accordance with Section 4.5 of this Agreement, this Agreement s hall continue in full force and effect, comm encing on June 15, 2022, and ending on the expiration of Omnia Partners Contract 2020002149.
4.5 Termination Prior to Expiration of Term . City may terminate this Agreement at any time, with or without cause, upon thirty (30) days written notice to Contractor. W here termination is due to the fault of Contractor and constitut es an immediate danger to health, safety, and general welfare, the period of notice shall be such shorter time as may be determined by the City . Upon receipt of the notice of t ermination, Contractor shall immediately cease all Services except such as may be specifically approved by the Contract Officer. Contractor shall be entitled to compensation for all Services rendered prior to receipt of the notice of termination and for any Services authorized by the Contract Officer after such notice. City shall not be liable for any costs other than the charges or portions thereof which are specified herein. Contractor shall not be entitled to payment for unperformed Services and shall not be entitled to damages or compensation for termination o f Work. If the te rmination is for cause, the City shall have the right to take whatever steps it deems necessary to correct Contractor's deficiencies and charge the cost thereof to Contractor, w ho shall be liable for the full cost of the City's corrective action.
Contractor may not terminate this Agreement except for cause, upon thirty (30) days written notice to City.
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 4 of 17
5. COORDINATION OF WORK
5.1 Representative of Contractor. The following princ ipal of Contractor is designated as being the prin cipal and representative of Contractor authorized to act and make all decisions in its behalf with respect to the specified Services: Noelle Minite (name), Account Executive (title). It is expressly understood that the experience, knowledge, education, capability, and reputation of the foregoing principal is a substantial inducement for City to enter into this Agreement. Therefore, the foregoing principal shall be responsible during the term of this Agree ment for directing all activities of Contractor and devoting sufficient time to personally supervise the Services under this Agreement.
5.2 Contract Officer . The Contract Officer shall be the City Manager or his/her designee ("Contract Officer"). Contractor shall be responsible for keeping the Contract Officer fully informed of t he progress of the performance of the Services. Contractor shall refer any decisions that must be made by City to the Contract Officer. Unless otherwise specified, any approval of City shall mean the approval of the Contract Officer.
5.3 Prohibition Again st Subcontracting or Assignment . The experience, knowledge, education, capability, and reputation of Contractor, its principals, and employees, were a substantial inducement for City to enter into this Agreement. In addition, neither thi s Agreement nor a ny interest may be assigned or transferred, voluntarily or by operation of law, without the prior written approval of City , except to an affiliate of Contractor . Subcontracts, if any, shall contain a provision making them subject to all pr ovisions stipulated in this Agreement including without limitation the insurance and indemnification requirements. If Contractor is permitted to subcontract any part of this Agreement by City, C ontractor shall be responsible to City for the acts and omiss ions of its subco ntractor(s) in the same manner as it is for persons directly employed. Nothing contained in this Agreement shall create any contractual relationships between any subcontractor and City.
5.4 Independent Contractor. Neither City nor any of its employees sh all have any control over the manner, mode, or means by which Contractor, its agents, or employees, perform the Services required, except as otherwise specified. Contractor shall perform all required Services as an independent contractor of City and shall not be an employee of City and shall remain at all times as to City a wholly independent contractor with only such obligations as are consistent with that role; however, City shall have the right to review Contractor’s work product, result, and advice. Contractor shall not at any time or in any manner represent that it or any of its agents or employees are agents or employees of City. Contractor shall pay all wages, salaries, and other amounts due personnel in connection with their performance under this Agreement and as required by law. Contractor shall be responsible for all reports and obligations respecting such personnel, including, but not limited to: social security taxes , income tax withholding, unemployment insurance, and workers ’ compensation i nsurance. Contractor shall not have any authority to bind City in any manner.
5.5 Personnel. Contractor agrees to assign the following individuals to perform the services in this Agreement. Contractor shall not alter the assignment of th e following personnel without providing written notice to the Contract Officer. Acting through the City Manager, the DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 5 of 17
City shall have the unrestricted right to order the removal of any personnel assigned by Contractor by providing written notice to Contractor.
Name: Title:
Noelle Minite Account Executive
5.6 California Labor Code Requirements.
A. Contractor is aware of the requirements of California Labor Code Sections 1720 et seq. and 17 70 et seq., which require the payment of prevailing wage rate s and the performance of other requirements on certain “public works” and “maintenance” projects (“Prevailing Wage Laws”). If the Services are being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing W age Laws, and if the total compensation is $15,000 or more for maintenance or $25,000 or more for construction, alteration, demolition, installation, or repair, Contractor agrees to fully comply with such Prevailing Wage Laws. Contractor shall defend, indemnify, and hold the City, its officials, officers, employees, and agents free and harmless from any claims, liabilities, costs, penalties, or interest arising out of any failure or alleged failure to comply with the Prevailing Wage Laws. It shall be mandato ry upon the Contractor and all subcon tractors to comply with all California Labor Code provisions, which include but are not limited to prevailing wages (Labor Code Sections 1771, 1774 and 1775), employment of apprentices (Labor Code Section 1777.5), certified payroll records (Labor Code Sections 1771.4 and 1776), hours of labor (Labor Code Sections 1813 and 1815) and debarment of contractors and subcontractors (Labor Code Section 1777.1).
B. If the Services are being performed as part of an applicable “public works” or “maintenance” project and if the total compensation is $15,000 or more for maintenance or $25,000 or more for construction, alteration, demolition, installation, or repair, then pu rsuant to Labor Code Sections 1725.5 and 1771.1, the Contractor and all su bcontractors performing such Services must be registered with the Department of Industrial Relations. Contractor shall maintain registration for the duration of the Project and requ ire the same of any subcon tractors, as applicable. This Agreement may also be subject to compliance monitoring and enforcement by the Department of Industrial Relations. It shall be Contractor’s sole responsibility to comply with all applicable registration and labor compliance requirements.
6. INSURANCE
Contractor shall procure and maintain, at its sole cost and expense, policies of insurance as set forth in the attached Exhibit "B", incorporated herein by reference.
7. INDEMNIFICATION.
7.1 Indemnification. To the fullest extent permitted by law, Contractor shall defend (at Contractor’s sole cost and expense), indemnify, protect, and hold harmless City, its elected officials, officers, employees, agents, and volunteers (collectively the “Indemnified Parties”), from and against any and all third party liabilities, actions, suits, claims, demands, losses, costs, judgments, arbitration awards, settlements, damages, demands, orders, penalties, and expenses including legal costs and attorney fees (collectively “Claims”), including but not DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 6 of 17
limited to Claims arising from injuries to or death of persons (Contractor’s employees included), for damage to property, including property owned by City, for any violation of any federal, state, or local law or ordinanc e or in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct committed by Contractor, its officers, employees , representatives, and agents, that arise out of or relate to Contractor’s performance of Services or this Agreement. This indemnification clause excludes Claims arising from the sole negligence or willful misconduct of the Indemnified Parties . Under no circumstances shall the insurance requirements and limits set forth in this Agreement be c onstrued to limit Contractor’s indemnification obligation or other liability under this Agreement. Contractor’s indemnification obligation shall survive the expiration or earlier termination of this Agreement until all actions against the Indemnified Part ies for such matters indemnified are fully and finally barred by the applicable statute of limitations or, if an action is timely filed, until such action is final.
7.2 Design Professional Services Indemnification and Reimbursement. If Contractor’s ob ligation to defend, indemnify, and/or hold harmless arises ou t of Contractor’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fu lly incorporated herein, Contractor’s indemnification obligat ion shall be limited to the extent which the C laims arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Contractor in the performance of the Services or this Agreement, and, upon Contractor obtaining a final ad judication by a court of competent jurisdiction, Contractor’s liability for such claim, including the cost to defend, shall not exceed the Contractor’s proportionate percentage of fault.
8. RECORDS AND REPORTS
8.1 Reports. Contractor shall periodically prepare and submit to the Contract Officer reports concerning the performance of the Services required by this Agreement , or as the Contract Officer shall require.
8.2 Records. Contractor shall keep complete, accurate, and detailed accounts of all time, c osts, expense s, and expenditures pertainin g in any way to this Agreement. Contractor shall keep such books and records as shall be necessary to properly perform the Services required by this Agr eement and enable the Contract Officer to evaluate the perfor mance of such Services. The Contract Officer shall have full and free access to such books and records at all reasonable times, including the right to inspect, copy, audit on not more than an annual basis, and make records and transcripts from such records.
8.3 Ownership of Documents . All drawings, specifications, reports, records, documents, and other materials prepared by Contractor in the performance of this Agreement shall be the property o f Contractor. City shall have an unrestricted right to use t he concepts embodied in such documents.
8.4 Release of Documents . All drawings, specifications, reports, records, documents, and other materials prepared by Contractor in the performance of Services under this Agreement shall not be released publicly with out the prior written approval of the Contract Officer.
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 7 of 17
8.5 Audit and Inspection of Records . After receipt of reasonable notice and during the regular business hours of City, Contractor shall pr ovide City, or other agents of City, such access to Contractor’s books, records, payroll documents, and facilities as City deems necessary to examine, copy, audit, and inspect all accounting books, records, work data, documents, and activities directly related to Contractor’s performance under this Agreement on no more than an annual basis. Contractor shall maintain such books, records, data, and documents in accordance with generally accepted accounting principles and shall clearly identify and make such items readily accessible to such parties during the term of t his Agreement and for a period of three (3) years from the date of final payment by City hereunder.
9. ENFORCEMENT OF AGREEMENT
9.1 California Law. This Agreement shall be construed and interpre ted both as to validity and to performance of the parties in accordance with the laws of the State of California.
Legal actions concerning any dispute, claim , or matter arising out of or in relation to this Agreement shall be instituted in the Superior Co urt of the County of Riverside, State of California, or any other appropriate court in such county, and Contractor covenants and agrees to submit to the personal jurisdiction of such court in the event of such action.
9.2 Interpretation. This Agreement sh all be construed as a whole according to its fair language an d common mean ing to achieve the objectives and purposes of the Parties. The terms of this Agreement are contractual and the result of negotiation between the Parties.
Accordingly, any rule of construction of contracts (including, without limitation, California Civil Code Section 1654) that ambiguities are to be construed against the drafting party, shall not be employed in the interpretation of this Agreement. The caption headings of the various sections and paragraphs of this Agreement are for convenienc e and identification purposes only and shall not be deemed to limit, expand, or define the contents of the respective sections or paragraphs.
9.3 Waiver. No delay or omission in the exercise of any right or remedy of a non - defaulting Party on any default shall impair such right or remedy or be construed as a waiver.
No consent or approval of City shall be deemed to waive or render unnecessary City’s consent to or approval of any subsequent act of Contractor. Any waiver by either Party of any default must be in writing. No such waiver shall be a waiver of any other default concerning the same or any other provision of this Agreement.
9.4 Rights and Remedies are Cumulative . Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative . The exercise by either Party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other Party.
9.5 Legal Action. In addition to any other rights or remedies, either Party may take legal action, in law or in equity, to cure, correct , or remedy any default, to recover damages for any default, to comp el specific p erformance of this Agreement, to obtain injunctive relief, a declaratory judgment, or any other remedy consistent with the purposes of this Agreement.
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 8 of 17
9.6 Attorney Fees. In the event any dispute between the Parties with respect to this Agreement results i n litigation or any non -judicial proceeding, the prevailing Party shall be entitled, in addition to such other relief as may be granted, to recover from the non -prevailing Party all reasonable costs and expenses. These include but are not lim ited to reasonable attorney fees, expert contractor fees, court costs and all fees, costs, and expenses incurred in any appeal or in collection of any judgment entered in such proceeding.
10. CITY OFFICERS AND EMPLOYEES: NON-DISCRIMINATION
10.1 Non-Liability of City Officers and Employees. No officer or employee of City shall be personally liable to the Contractor, or any successor -in-interest, in the event of any default or breach by City or f or any amount which may become due to the Contractor or its successor, or for breach of any obligation of the terms of this Agreement.
10.2 Conflict of Interest. Contractor acknowledges that no officer or employee of the City has or shall have any direct or indirect financial interest in this Agreement, nor shall Contractor enter into any agreement of any kind with any such officer or employee during the term of this Agreement and for one (1) year thereafter. Contractor warrants that Contractor has not paid or given, and will not pay or give, any third party any m oney or other consideration in exchange for obtaining this Agreement.
10.3 Covenant Against Discrimination . In connection with its performance under this Agreement, Contractor shall not discrim inate against any employee or applicant for employment becaus e of actual o r perceived race, religion, color, sex, age, marital status, ancestry, national origin ( i.e., place of origin, immigration status, cultural or linguistic characteristics, or ethnicit y), sexual orientation, gender identity, gender expression, p hysical or mental disability, or medical condition (each a “prohibited basis”). Contractor shall ensure that applicants are employed, and that employees are treated during their employment, without regard to any prohibited basis. As a condition precedent t o City’s lawf ul capacity to enter this Agreement, and in executing this Agreement, Contractor certifies that its actions and omissions hereunder shall not incorporate any discrimination arising f rom or related to any prohibited basis in any Contractor acti vity, including but not limited to the following: employment, upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship; and further, that Contractor is in full compliance with the provisions of Palm Springs Municipal Code Section 7.09.040, including without limitation the provision of benefits, relating to non - discrimination in city contracting.
11. MISCELLANEOUS PROVISIONS
11.1 Notice. Any notice, demand, request, consent, approval, or communication that either Party desires, or is required to give to the other Party or any other person shall be in writing and either served personally or sent by pre -paid, first -class mai l or overnigh t delivery service to the address set forth below. Notice shall be deemed communicated seventy-two (72) hours from the time of mailing if mailed as provided in this Section. Either Party may change its address by notifying the other Party of the change of address in writing.
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 9 of 17
To City: City of Palm Springs
Attention: City Manager/ City Clerk
3200 E. Tahquitz Canyon Way
Palm Springs, California 92262
To Contractor: Mohawk Commercial, Inc.
160 S. Industrial Blvd.
Calhoun, GA 30701
Attn: General Counsel
With a copy to: Contract and Compliance
Attention: Noelle Minite
11.2 Integrated Agreement . This Agreement constitutes the entire understanding between the Parties and supersedes and cancels all prior negotiations, arrangem ents, agreements, representations, and understandings, if any, made by or among the Parties with respect to the subject matter in this Agreement.
11.3 Amendment. No amendments or other modific ations of this Agreement shall be binding unless through written agreement signed by all Parties.
11.4 Severability. Whenever possible, each provision of this Agreement shall be interpreted in such a manner as to be effective and valid under applicable la w. In the event that any one or more of the phrases, sentenc es, clauses, pa ragraphs, or sections contained in this Agreement shall be declared invalid or unenforceable by valid judgment or decree of a court of competent jurisdiction, such invalidity or un enforceability shall not affect any of the remaining phrases, sentences, clauses, paragraphs, or sections of this Agreement, which shall be interpreted to carry out the intent of the Parties.
11.5 Successors in Interest . This Agreement shall be binding upo n and inure to the benefit of the Parties’ successors and assignees.
11.6 Third Party Beneficiary . Except as may be expressly provided for in this Agreement, nothing contained in this Agreement is intended to confer, nor shall this Agreement be construed as conferring, any rights, including, without limitation, any rights as a third-party beneficiary or otherwise, upon any entity or person not a party to this Agreement.
11.7 Recitals. The above -referenced Recitals are hereby incorporated into the Agreement as though fully set forth in this Agreement and each Par ty acknowledges and agrees that such Party is bound, for purposes of this Agreement, by the same.
11.8 Authority. The persons executing this Agreement on behalf of the Parties warrant that they are duly authorized to execute this Agreement on behalf of Parties and that by so executing this Agreement the Parties are formally bound to the provisions of this Agreement.
11.9 Counterparts. This Agreement may be signed in counterparts, each of which shall constitute an original.
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 10 of 17
[SIGNATURES ON NEXT PAGE]
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 11 of 17
SIGNATURE PAGE TO AGREEMENT BY AND BETWEEN THE CITY OF PALM SPRINGS AND MOHAWK COMMERCIAL, INC.
IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below.
CONTRACTOR:
By: _______________________________________ By: _________________________________________ Signature Signature
(2nd signature required for Corporations)
Date: Date:
CITY OF PALM SPRINGS:
APPROVED BY CITY COUNCIL:
Date: N/A Item No. N/A
APPROVED AS TO FORM: ATTEST:
By: ___________________________ By: _______________________________ Jeffrey S. Ballinger, Monique Lomeli,
City Attorney City Clerk
APPROVED:
By: _______________________________ Date:
City Manager – over $50,000
Deputy/Assistant City Manager – up to $50,000
Director – up to $25,000
Manager – up to $5,000
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 6/16/2022
6/16/2022
6/16/2022
55575.00001\40098778.2
Revised 2.9.22 Page 12 of 17
EXHIBIT “A”
CONTRACTOR’S
SCOPE OF SERVICES/WORK
Including,
Schedule of Fees
And
Schedule of Performance
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 13 of 17
The scope of the services will be as outlined in the Omnia Partners Contract 2020002149.
Services include systemwide flooring and installation services. Prices are a not-to-exceed as outlined on the following pages for the current year.
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C Contract: Omnia Partners
Freight Terms: FOB Destination
Prepaid & Add
Contract Expiration: 4/14/2025
Product Platform Style Name Style # Backing Size UOM Collection Fiber Brand Dye Method UC Approved Materials of Concern PROP 65 EPD List Price 2022 Price Broadloom A Different Angle KC234 Woven (W) 12' Wide SY Modern Dobby Duracolor® Tricor Premium Nylon Solution Dyed Yes NONE NO YES 79.76$ 76.11$ Broadloom Accompany / QS BC534 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Agnomen / QS BC552 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Alexian / QS BC540 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Allegorist BC512 Weldlok 12' Wide SY Yarn Spinner/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Alnwick Castle SLC50 Weldlok 12' Wide SY Residence Everstrand® SD Solution Dyed Yes Alumina Trihydrate (FR) NO NO 10.78$ 10.28$ Broadloom Amend Art / QS BC531 Weldlok 12' Wide SY Social Orde r Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 27.76$ 24.79$ Broadloom Ancillary / QS BC532 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Anecdotist BC514 Weldlok 12' Wide SY Yarn Spinner/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Antipole / QS BC545 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Applied Art KC217 Woven (W) 12' Wide SY Industrial Design Duracolor® Tricor Premium Nylon Solution Dyed Yes NONE NO YES 55.62$ 53.08$ Broadloom Applied Science KC218 Woven (W) 12' Wide SY Industrial Design Colorstrand Solution Dyed Yes NONE NO YES 62.97$ 60.09$ Broadloom Artist II / QS BC380 Weldlok 12' Wide SY Pure Genius II Colorstrand Solution Dyed/Yarn Dyed Alumina Trihydrate (FR) NO YES 16.99$ 16.21$ Broadloom Auteur BC513 Weldlok 12' Wide SY Yarn Spinner/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Balance Refresh / QS BC549 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Balanced Weave KC275 Woven (W) 12' Wide SY Sunweave Duracolor® Tricor Premium Nylon Solution Dyed Yes NONE NO YES 66.12$ 63.10$ Broadloom Base Camp / QS BC332 Weldlok 12' Wide SY Explorations Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 16.47$ 15.72$ Broadloom Broken Checks / QS BC403 Unibond Plus 12' Wide SY Intertwined Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 30.04$ 29.33$ Broadloom Celestial Being / QS BC541 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom CEO II / QS BC382 Weldlok 12' Wide SY Pure Genius II Colorstrand Solution Dyed/Yarn Dyed Alumina Trihydrate (FR) NO YES 16.05$ 15.31$ Broadloom Clearly Classic KC221 Woven (W) 12' Wide SY Simply Tailored Colorstrand Solution Dyed Yes NONE NO YES 70.31$ 67.10$ Broadloom Color Study 30 / QS BC574 Weldlok 12' Wide SY Color Study Colorstrand Piece Dyed Alumina Trihydrate (FR) NO YES 21.40$ 20.43$ Broadloom Color Study 36 BC575 Weldlok 12' Wide SY Color Study Colorstrand Piece Dyed Alumina Trihydrate (FR) NO YES 26.76$ 25.54$ Broadloom Color Study 42 BC576 Weldlok 12' Wide SY Color Study Colorstrand Piece Dyed Alumina Trihydrate (FR) NO YES 34.68$ 33.09$ Broadloom Comeback / QS BC546 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Connetic / QS/ Max Service BC426 Unibond Plus 12' Wide SY Connetic Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 16.18$ 15.43$ Broadloom Consul / QS BC539 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Contra / QS BC555 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Convenio BC506 Weldlok 12' Wide SY Yarn Spinner/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Conveyor / QS BC538 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Countless Variations BC570 Weldlok 12' Wide SY Open Narrative/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Country Mile / QS BC550 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Crestmont Ave SLC39 Weldlok 12' Wide SY 100% Mohawk EverStrand BCF P.E.T. Piece Dyed Alumina Trihydrate (FR) NO NO 23.33$ 20.19$ Broadloom Croft Manor SLC51 Weldlok 12' Wide SY Residence Everstrand® SD Solution Dyed Yes Alumina Trihydrate (FR) NO NO 17.08$ 16.31$ Broadloom Cross Knit / QS BC375 Unibond Plus 12' Wide SY Fiber Art Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 18.52$ 17.67$ Broadloom Denouement BC564 Weldlok 12' Wide SY Open Narrative/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Doctor II / QS / Max Service BC381 Weldlok 12' Wide SY Pure Genius II Colorstrand Solution Dyed/Yarn Dyed Alumina Trihydrate (FR) NO YES 14.92$ 14.24$ Broadloom Drifting Current BC578 Weldlok 12' Wide SY Urban Shores Colorstrand Solution Dyed Yes Alumina Trihydrate (FR) NO YES 46.78$ 44.64$ Broadloom Driven / QS / Max Service BC427 Unibond Plus 12' Wide SY Mass Influence Colorstrand Solution Dyed/Yarn Dyed Alumina Trihydrate (FR) NO YES 16.18$ 15.43$ Broadloom Elocutionist BC509 Weldlok 12' Wide SY Yarn Spinner/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Empyrean / QS BC544 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom End Result / QS BC288 Weldlok 12' Wide SY Of The Moment Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 13.78$ 13.15$ Broadloom Essential Elements / QS / Max Service BC441 Weldlok 12' Wide SY Remastered Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 14.92$ 14.24$ Broadloom Existence KC229 Unibond Plus 12' Wide SY Telling Spaces Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 38.76$ 36.99$ Broadloom Faculty Remix GL154 Unibond Plus 12' Wide SY Faculty Remix Duracolor Solution Dyed/Yarn Dyed Alumina Trihydrate (FR) NO YES 35.08$ 32.16$ Broadloom Fiction Film BC565 Weldlok 12' Wide SY Open Narrative/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Floating Forms BC579 Weldlok 12' Wide SY Urban Shores Colorstrand Solution Dyed Yes Alumina Trihydrate (FR) NO YES 46.78$ 44.64$ Broadloom Flow of Life BC567 Weldlok 12' Wide SY Open Narrative/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Fragmented Narrative BC566 Weldlok 12' Wide SY Open Narrative/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Gathered Style / QS BC404 Unibond Plus 12' Wide SY Intertwined Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 30.04$ 29.33$ Broadloom Get Started / QS / Max Service BC406 Weldlok 12' Wide SY Get Started PET Solution Dyed UC Approved Alumina Trihydrate (FR) NO NO 12.04$ 11.33$ Broadloom Global Attraction KC222 Woven (W) 12' Wide SY Colorstrand Solution Dyed / Yarn Dyed NONE NO YES 75.56$ 72.11$ Broadloom Good Will B
C528 Weldlok 12' Wide SY Social Orde r Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 27.76$ 24.79$ Broadloom Goonj Revival / QS 4 week MH361 Weldlok 12' Wide SY Definity (rolls/cuts/rugs) Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 88.18$ 71.92$ Broadloom Graphic Touch / QS / Max Service BC452 Weldlok 12' Wide SY High Concepts PET Solution Dyed UC Approved Alumina Trihydrate (FR) NO NO 12.04$ 11.49$ Broadloom Heterdigetic B
C561 Weldlok 12' Wide SY Open Narrative/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Hue-Ology BC573 Weldlok 12' Wide SY Hueology Colorstrand Piece Dyed Alumina Trihydrate (FR) NO YES 27.34$ 26.09$ Broadloom Humble KC227 Unibond Plus 12' Wide SY Telling Spaces Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 41.92$ 40.00$ Broadloom Innate Spirit (Temp Stock Definity) BC581 Weldlok 12' Wide SY Celebrating Heritage Colorstrand Solution Dyed Yes Alumina Trihydrate (FR) NO YES 88.18$ 84.15$ Broadloom Interplay / QS GL415 Unibond Plus 12' Wide SY Learn & Live Duracolor Tricor Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 27.34$ 22.70$ Broadloom Interplay Stripe / QS GL416 Unibond Plus 12' Wide SY Learn & Live Duracolor Tricor Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 27.34$ 22.70$ Broadloom Ivy Hall SLC46 Weldlok 12' Wide SY 100% Mohawk EverStrand BCF P.E.T. Predyed Alumina Trihydrate (FR) NO NO 10.49$ 9.17$ Broadloom Jocund / QS BC529 Weldlok 12' Wide SY Social Orde r Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 27.76$ 24.79$ Broadloom Lakir Revival / QS 4 week MH362 Weldlok 12' Wide SY Definity (rolls/cuts/rugs) Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 88.18$ 71.92$ Broadloom Laurel Path SLC34 Weldlok 12' Wide SY Colorstrand® SD Nylon Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 26.96$ 24.79$ Broadloom Linear Fiction BC571 Weldlok 12' Wide SY Open Narrative/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Listener BC511 Weldlok 12' Wide SY Yarn Spinner/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Living Quarters SLC26 Weldlok 12' Wide SY 75% SmartStrand® Ultra™ BCF Triexta / 25% BCF P.E.T. Piece Dyed Alumina Trihydrate (FR) NO YES 16.15$ 15.60$ Broadloom Lyrical Documentary BC559 Weldlok 12' Wide SY Open Narrative/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Matte Finish GL421 Unibond Plus 12' Wide SY Texural Effects Duracolor Tricor Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 31.63$ 29.22$ Broadloom Mill Avenue SLC41 Weldlok 12' Wide SY 100% SmartStrand® Ultra™ BCF Triexta Piece Dyed Alumina Trihydrate (FR) NO YES 14.46$ 12.42$ Broadloom Mindful - 20 (15 ft) BC411 Weldlok 12' Wide SY Mindful PET Solution Dyed UC Approved Alumina Trihydrate (FR) NO NO 10.78$ 9.17$ Broadloom Mindful - 20 / QS BC395 Weldlok 12' Wide SY Mindful PET Solution Dyed Yes Alumina Trihydrate (FR) NO NO 8.98$ 8.57$ Broadloom Mindful - 26 (15 ft) BC412 Weldlok 12' Wide SY Mindful PET Solution Dyed UC Approved Alumina Trihydrate (FR) NO NO 13.12$ 11.00$ Broadloom Mindful - 26 / QS / Max Service BC396 Weldlok 12' Wide SY Mindful PET Solution Dyed Yes Alumina Trihydrate (FR) NO NO 12.04$ 11.49$ Broadloom Mindful - Base / QS BC397 Weldlok 12' Wide SY Mindful PET Solution Dyed Yes Alumina Trihydrate (FR) NO NO 8.26$ 7.88$ Broadloom Mirada Stitchlock / QS GL417 Unibond Plus 12' Wide SY Learn & Live Duracolor Tricor Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 26.80$ 22.70$ Broadloom Moss Moderne GL420 Unibond Plus 12' Wide SY Texural Effects Duracolor Tricor Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 31.63$ 30.27$ Broadloom Must Have / QS / Max Service BC287 Weldlok 12' Wide SY Of The Moment Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 14.92$ 14.24$ Broadloom New Basics III 20 / QS / Max Service BC398 Weldlok 12' Wide SY New Basics Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 14.92$ 14.17$ Broadloom New Basics III 26 / QS / Max Service BC399 Unibond Plus 12' Wide SY New Basics Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 16.18$ 16.07$ Broadloom New Leaf / QS BC554 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.42$ Broadloom Oblique / QS BC536 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.42$ Broadloom Observational B
C563 Weldlok 12' Wide SY Open Narrative/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Outrider / QS BC543 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Overarching BC569 Weldlok 12' Wide SY Open Narrative/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Patterned Past KC276 Woven (W) 12' Wide SY Pattern & Symmetry Duracolor® Tricor Premium Nylon Solution Dyed UC Approved NONE NO YES 67.18$ 55.12$ Broadloom Pocket Square KC225 Woven (W) 12' Wide SY Simply Tailored Duracolor® Tricor Premium Nylon Solution Dyed UC Approved NONE NO YES 70.54$ 53.30$ Broadloom Profor BC515 Weldlok 12' Wide SY Yarn Spinner/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Protagonist BC510 Weldlok 12' Wide SY Yarn Spinner/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Purview / QS BC553 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Quarterage SLC32 Weldlok 12' Wide SY 100% SmartStrand® Ultra™ BCF Triexta Piece Dyed Alumina Trihydrate (FR) NO YES 26.46$ 25.24$ Broadloom Real Time BC568 Weldlok 12' Wide SY Open Narrative/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Recover Act / QS BC547 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Resistance / QS / Max Service BC428 Unibond Plus 12' Wide SY Mass Influence Colorstrand Solution Dyed/Yarn Dyed Alumina Trihydrate (FR) NO YES 16.18$ 15.43$ Broadloom Rhetorcian BC507 Weldlok 12' Wide SY Yarn Spinner/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Roundabout / QS BC556 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Rustic Plad KC277 Woven (W) 12' Wide SY Pattern & Symmetry Duracolor® Tricor Premium Nylon Solution Dyed UC Approved NONE NO YES 67.18$ 55.12$ Broadloom Schema BC508 Weldlok 12' Wide SY Yarn Spinner/Mohawk Today- 50 SY Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Second Wind / QS BC557 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Strategic Account Number: 16629
For order placement: MohawkOne West -
[email protected] | MohawkOne East -
Contract Inquiries: [email protected]
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C Broadloom Sequence of Events BC562 Weldlok 12' Wide SY Open Narrative/Mohawk Today- 50 S Y Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Shadow Pass KC271 Woven (W) 12' Wide SY Sunweave Duracolor® Tricor Premium Nylon Solution Dyed UC Approved NONE NO YES 66.12$ 55.12$ Broadloom Shape Up / QS BC558 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Sideward / QS BC537 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Sky Gap / QS BC551 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Smart Details / QS / Max Service BC451 Weldlok 12' Wide SY High Concepts PET Solution Dyed UC Approved Alumina Trihydrate (FR) NO NO 12.04$ 11.49$ Broadloom Social Identity BC572 Weldlok 12' Wide SY Open Narrative/Mohawk Today- 50 S Y Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Social Perk / QS BC530 Weldlok 12' Wide SY Social Orde r Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 31.48$ 24.79$ Broadloom Spheroid / QS BC535 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Start Right / QS / Max Servic e BC453 Weldlok 12' Wide SY High Concepts PET Solution Dyed UC Approved Alumina Trihydrate (FR) NO NO 12.04$ 11.49$ Broadloom Storied Pieces BC580 Weldlok 12' Wide SY Celebrating Heritage Colorstrand Solution Dyed Yes Alumina Trihydrate (FR) NO YES 46.78$ 44.64$ Broadloom Subsidiary / QS BC533 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Suburbia SLC27 Weldlok 12' Wide SY 100% Mohawk EverStrand BCF P.E.T. Piece Dyed Alumina Trihydrate (FR) NO NO 19.83$ 15.60$ Broadloom Surreal Adver t BC560 Weldlok 12' Wide SY Open Narrative/Mohawk Today- 50 S Y Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 53.05$ 50.62$ Broadloom Trail Mix / QS / Max Service BC333 Weldlok 12' Wide SY Explorations Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 14.92$ 14.24$ Broadloom Uncommon Thread KC233 Woven (W) 12' Wide SY Modern Dobb y Duracolor® Tricor Premium Nylon Solution Dyed UC Approved NONE NO NO 61.92$ 51.54$ Broadloom Vicar / QS BC542 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Waft / QS BC548 Weldlok 12' Wide SY Domicile Colorstrand Precision Dyed Injection Alumina Trihydrate (FR) NO YES 48.97$ 40.41$ Broadloom Well Dressed KC226 Woven (W) 12' Wide SY Simply Tailored Duracolor® Tricor Premium Nylon Solution Dyed UC Approved NONE NO YES 90.24$ 74.51$ Broadloom Whip Stitch / QS / Max Service BC376 Unibond Plus 12' Wide SY Fiber Ar t Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 16.18$ 15.43$ Broadloom Wired Mesh / QS BC393 Unibond Plus 12' Wide SY Metal Craf t Colorstrand Solution Dyed UC Approved Alumina Trihydrate (FR) NO YES 22.16$ 21.15$ Modular Carpet Tile A Premonition II GT161 EcoFlex NXT (EP) 2424 SY Sixth Sense II Duracolo r Solution Dyed UC Approved NONE NO YES 65.32$ 63.18$ Modular Carpet Tile Academic View / QS / Max Service BT433 EcoFlex Matrix (UZ) 2424 SY Art Exposure Colorstrand Solution Dyed UC Approved NONE NO YES 22.12$ 21.10$ Modular Carpet Tile Accredited / QS GT431 EcoFlex NXT (EP) 1236 SY Learn & Live Duracolor Trico r Solution Dyed UC Approved NONE NO YES 38.88$ 33.98$ Modular Carpet Tile Adaptable / QS BT432 EcoFlex Matrix (UZ) 2424 SY Art Exposure EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 29.68$ 29.23$ Modular Carpet Tile Adopt a Plan GT466 EcoFlex NXT (EP) 2424 SY Learn & Live - Taking Steps Duracolor Trico r Solution Dyed Yes NONE NO YES 34.83$ 33.24$ Modular Carpet Tile Amplitude GT147 EcoFlex NXT (EP) 2424 SY Power Surg e Duracolor Solution Dyed UC Approved NONE NO YES 56.48$ 54.06$ Modular Carpet Tile Amused II GT313 EcoFlex NXT (EP) 2424 SY State of Mind III Duracolo r Solution Dyed UC Approved NONE NO YES 67.10$ 64.31$ Modular Carpet Tile Angled Perception / QS BT496 EcoFlex Matrix (UZ) 1236 SY Visual Edge EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 29.50$ 26.66$ Modular Carpet Tile Aqua Rhythm GT455 EcoFlex NXT (EP) 1236 SY Data Tide Duracolor Trico r Solution Dyed Yes NONE NO YES 43.00$ 41.04$ Modular Carpet Tile Artist II / QS BT380 EcoFlex Matrix (UZ) 2424 SY Pure Genius II EcoFlex Matrix Solution Dyed/Yarn Dyed NONE NO YES 32.92$ 32.73$ Modular Carpet Tile Baccharis GT408 EcoFlex NXT (EP) 1236 SY Healthy Environments Duracolor Trico r Solution Dyed UC Approved NONE NO YES 45.54$ 43.53$ Modular Carpet Tile Biome GT456 EcoFlex NXT (EP) 1236 SY Data Tide Duracolor Trico r Solution Dyed Yes NONE NO YES 43.00$ 41.04$ Modular Carpet Tile Blended Twist / QS BT413 EcoFlex Matrix (UZ) 2424 SY Artisanal EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 23.56$ 22.49$ Modular Carpet Tile Brain Power GT136 EcoFlex NXT (EP) 2424 SY Mind Over Matte r Duracolor Solution Dyed UC Approved NONE NO YES 42.64$ 40.70$ Modular Carpet Tile Caliber / QS BT282 EcoFlex Matrix (UZ) 2424 SY Bending Earth EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 32.49$ 32.10$ Modular Carpet Tile Central Point / QS BT428 EcoFlex Matrix (UZ) 2424 SY Art Intervention EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 28.62$ 26.48$ Modular Carpet Tile CEO II / QS BT382 EcoFlex Matrix (UZ) 2424 SY Pure Genius II EcoFlex Matrix Solution Dyed/Yarn Dyed NONE NO YES 32.92$ 32.73$ Modular Carpet Tile ChillD GT424 EcoFlex NXT (EP) 1236 SY Relaxing Floors Duracolor Trico r Solution Dyed UC Approved NONE NO YES 57.33$ 52.98$ Modular Carpet Tile Chitalpa GT407 EcoFlex NXT (EP) 1236 SY Healthy Environments Duracolor Trico r Solution Dyed UC Approved NONE NO YES 45.54$ 43.53$ Modular Carpet Tile Clever Class / QS BT408 EcoFlex Matrix (UZ) 2424 SY Mixology EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 22.12$ 20.96$ Modular Carpet Tile Color Balance GT405 EcoFlex NXT (EP) 1236 SY Color Balance Duracolo r Solution Dyed UC Approved NONE NO YES 44.89$ 42.90$ Modular Carpet Tile ColorBeat GT160 EcoFlex NXT (EP) 2424 SY Colorbea t Duracolor Tricor Solution Dyed UC Approved NONE NO YES 48.38$ 44.93$ Modular Carpet Tile ColorBeat Plank GT298 EcoFlex NXT (EP) 1236 SY Colorbea t Duracolor Tricor Solution Dyed UC Approved NONE NO YES 53.06$ 50.77$ Modular Carpet Tile Coolly Noted / QS BT336 EcoFlex Matrix (UZ) 2424 SY Mixology EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 22.12$ 20.96$ Modular Carpet Tile Crafted Expression GT459 EcoFlex NXT (EP) 1236 SY Celebrated Heritag e Duracolor Tricor Solution Dyed Yes NONE NO YES 53.55$ 51.11$ Modular Carpet Tile Creative Spark / QS / Max Service BT426 EcoFlex Matrix (UZ) 2424 SY Art Intervention Colorstrand Solution Dyed UC Approved NONE NO YES 22.12$ 21.10$ Modular Carpet Tile Datum / QS BT284 EcoFlex Matrix (UZ) 2424 SY Bending Earth EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 32.49$ 32.10$ Modular Carpet Tile Diffuse BT425 EcoFlex NXT (EP) 1236 SY Variant Form EcoFlex NXT Solution Dyed UC Approved NONE NO YES 42.84$ 41.32$ Modular Carpet Tile Digital Terrain Plank GT341 EcoFlex NXT (EP) 1236 SY Expedition Duracolor Trico r Solution Dyed UC Approved NONE NO YES 52.06$ 49.61$ Modular Carpet Tile Disruptive Path / QS BT430 EcoFlex NXT (EP) 1236 SY Art Style EcoFlex NXT Solution Dyed UC Approved NONE NO YES 41.11$ 40.12$ Modular Carpet Tile Doctor II / QS BT381 EcoFlex Matrix (UZ) 2424 SY Pure Genius II EcoFlex Matrix Solution Dyed/Yarn Dyed NONE NO YES 32.92$ 32.73$ Modular Carpet Tile Draft Point / QS / Max Service BT427 EcoFlex Matrix (UZ) 2424 SY Art Intervention Colorstrand Solution Dyed UC Approved NONE NO YES 22.12$ 21.10$ Modular Carpet Tile Drifted Ground Plank / QS BT389 EcoFlex NXT (EP) 1236 SY Iconic Earth Colorstrand Solution Dyed Yes NONE NO YES 42.41$ 40.47$ Modular Carpet Tile Ecosphere / QS GT333 EcoFlex NXT (EP) 2424 SY Expedition Duracolor Trico r Solution Dyed UC Approved NONE NO YES 45.32$ 43.33$ Modular Carpet Tile Enlivened / QS / Max Service BT455 EcoFlex Matrix (UZ) 2424 SY Art Exposure Colorstrand Solution Dyed UC Approved NONE NO YES 22.12$ 21.10$ Modular Carpet Tile Enthralled II GT314 EcoFlex NXT (EP) 2424 SY State of Mind III Duracolo r Solution Dyed UC Approved NONE NO YES 67.10$ 64.31$ Modular Carpet Tile Faculty Remix GT154 EcoFlex NXT (EP) 2424 SY Faculty Remix Duracolo r Solution Dyed/Yarn Dyed NONE NO YES 50.72$ 48.53$ Modular Carpet Tile Feather GT434 EcoFlex NXT (EP) 1236 SY Owls Duracolor Trico r Solution Dyed UC Approved NONE NO YES 57.33$ 53.28$ Modular Carpet Tile Field Of View Dark GT449 EcoFlex NXT (EP) 1236 SY Optic Reset Duracolor Trico r Solution Dyed UC Approved NONE NO YES 36.77$ 33.06$ Modular Carpet Tile Field Of View Light GT450 EcoFlex NXT (EP) 1236 SY Optic Reset Duracolor Trico r Solution Dyed UC Approved NONE NO YES 36.77$ 33.06$ Modular Carpet Tile Field Overlay Dark GT403 EcoFlex NXT (EP) 1236 SY Lichen Duracolor Trico r Solution Dyed UC Approved NONE NO YES 46.58$ 44.44$ Modular Carpet Tile Filtering Form / QS BT583 EcoFlex Matrix (UZ) 2424 SY Crossing Curren t Colorstrand Solution Dyed Yes NONE NO YES 29.39$ 28.05$ Modular Carpet Tile First One Up II / QS BT443 EcoFlex NXT (EP) 2424 SY First One Up II EcoFlex NXT Solution Dyed UC Approved NONE NO YES 33.30$ 31.78$ Modular Carpet Tile FirstStep II / QS GT315 EcoFlex NXT (EP) 2424 SY Tuff Stuff II Duracolo r Solution Dyed UC Approved NONE NO YES 96.55$ 89.97$ Modular Carpet Tile Flamestitch III GT168 EcoFlex NXT (EP) 2424 SY Flamestitch Duracolo r Solution Dyed UC Approved NONE NO YES 57.74$ 55.29$ Modular Carpet Tile Flight GT435 EcoFlex NXT (EP) 1236 SY Owls Duracolor Trico r Solution Dyed UC Approved NONE NO YES 57.33$ 53.28$ Modular Carpet Tile Flux Foundation / QS BT585 EcoFlex Matrix (UZ) 2424 SY Shape & Flow Colorstrand Solution Dyed Yes NONE NO YES 29.50$ 28.15$ Modular Carpet Tile Flux Play / QS BT584 EcoFlex Matrix (UZ) 2424 SY Shape & Flow Colorstrand Solution Dyed Yes NONE NO YES 29.50$ 28.15$ Modular Carpet Tile Forward Vision GT135 EcoFlex NXT (EP) 2424 SY Mind Over Matte r Duracolor Solution Dyed UC Approved NONE NO YES 42.64$ 40.74$ Modular Carpet Tile Fractal GrounD GT425 EcoFlex NXT (EP) 1236 SY Relaxing Floors Duracolor Trico r Solution Dyed UC Approved NONE NO YES 57.33$ 52.98$ Modular Carpet Tile Framed Structure / QS / Max Service BT436 EcoFlex Matrix (UZ) 2424 SY Sketch Effect Colorstrand Solution Dyed UC Approved NONE NO YES 22.12$ 21.10$ Modular Carpet Tile Framed Structure / QS EcoFlex Air BT436 EcoFlex Air (UW) 2424 SY Sketch Effect Colorstrand Solution Dyed UC Approved NONE NO YES 32.65$ 24.26$ Modular Carpet Tile Gravitational Plank GT343 EcoFlex NXT (EP) 1236 SY Expedition Duracolor Trico r Solution Dyed UC Approved NONE NO YES 52.06$ 49.61$ Modular Carpet Tile Ground Cover GT402 EcoFlex NXT (EP) 1236 SY Lichen Duracolor Trico r Solution Dyed UC Approved NONE NO YES 63.20$ 60.44$ Modular Carpet Tile Headstrong / QS BT354 EcoFlex Matrix (UZ) 2424 SY Renegad e EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 30.62$ 29.22$ Modular Carpet Tile Hem GT178 EcoFlex NXT (EP) 2424 SY Denim Duracolo r Solution Dyed UC Approved NONE NO YES 39.24$ 37.44$ Modular Carpet Tile Hem Plank GT295 EcoFlex NXT (EP) 1236 SY Denim Duracolo r Solution Dyed UC Approved NONE NO YES 43.11$ 41.41$ Modular Carpet Tile Hidden Dimension / QS BT497 EcoFlex Matrix (UZ) 1236 SY Visual Edge Ecoflex Matrix Solution Dyed UC Approved NONE NO YES 29.50$ 28.38$ Modular Carpet Tile Horsepower II GT170 EcoFlex NXT (EP) 2424 SY Motorsport II Duracolo r Solution Dyed UC Approved NONE NO YES 60.08$ 57.55$ Modular Carpet Tile Hustle & Bustle GT307 EcoFlex NXT (EP) 2424 SY On The Scene Duracolor Trico r Solution Dyed UC Approved NONE NO YES 40.66$ 38.80$ Modular Carpet Tile Hydrosphere / QS GT332 EcoFlex NXT (EP) 2424 SY Expedition Duracolor Trico r Solution Dyed UC Approved NONE NO YES 45.32$ 43.33$ Modular Carpet Tile Hyper Earth Plank BT405 EcoFlex NXT (EP) 1236 SY Hyper Earth EcoFlex NXT Solution Dyed UC Approved NONE NO YES 44.30$ 42.85$ Modular Carpet Tile In The Loop / QS BT309 EcoFlex Matrix (UZ) 2424 SY Beyond Expectations EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 33.10$ 31.59$ Modular Carpet Tile Infinite Impact / QS / Max Service BT499 EcoFlex Matrix (UZ) 1236 SY Infinite Impac t Envirostrand Solution Dyed UC Approved NONE NO NO 18.88$ 16.51$ Modular Carpet Tile Inseam Plank GT297 EcoFlex NXT (EP) 1236 SY Denim Duracolo r Solution Dyed UC Approved NONE NO YES 43.11$ 41.14$ Modular Carpet Tile Insurgent BT367 EcoFlex Matrix (UZ) 2424 SY Renegad e EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 38.07$ 36.68$ Modular Carpet Tile Integrate BT423 EcoFlex NXT (EP) 2424 SY Variant Form EcoFlex NXT Solution Dyed UC Approved NONE NO YES 39.76$ 38.43$ Modular Carpet Tile Interthread / QS BT449 EcoFlex Matrix (UZ) 2424 SY Dexterit y EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 18.88$ 17.57$ Modular Carpet Tile Into It GT319 EcoFlex NXT (EP) 2424 SY Get SmAr t Duracolor Tricor Solution Dyed UC Approved NONE NO YES 41.20$ 38.74$ Modular Carpet Tile It's a Sign II GT162 EcoFlex NXT (EP) 2424 SY Sixth Sense II Duracolo r Solution Dyed UC Approved NONE NO YES 65.32$ 63.18$ Modular Carpet Tile Jean GT177 EcoFlex NXT (EP) 2424 SY Denim Duracolo r Solution Dyed UC Approved NONE NO YES 39.24$ 37.44$ Modular Carpet Tile Kinesthetic Plank GT317 EcoFlex NXT (EP) 1236 SY Get SmAr t Duracolor Tricor Solution Dyed UC Approved NONE NO YES 44.80$ 42.53$ Modular Carpet Tile Know-How GT137 EcoFlex NXT (EP) 2424 SY Mind Over Matte r Duracolor Solution Dyed UC Approved NONE NO YES 42.64$ 40.70$ Modular Carpet Tile Late Night GT306 EcoFlex NXT (EP) 2424 SY On The Scene Duracolor Trico r Solution Dyed UC Approved NONE NO YES 40.66$ 38.80$ Modular Carpet Tile Lateral Surface / QS BT314 EcoFlex Matrix (UZ) 2424 SY Bending Earth II EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 32.49$ 32.10$ Modular Carpet Tile Lithosphere / QS GT334 EcoFlex NXT (EP) 2424 SY Expedition Duracolor Trico r Solution Dyed UC Approved NONE NO YES 45.32$ 43.33$ Modular Carpet Tile Macro Bloom GT388 EcoFlex NXT (EP) 1236 SY Lichen Duracolor Trico r Solution Dyed UC Approved NONE NO YES 63.20$ 60.44$ Modular Carpet Tile Material Narratives GT458 EcoFlex NXT (EP) 1236 SY Celebrated Heritag e Duracolor Tricor Solution Dyed Yes NONE NO YES 53.55$ 51.11$ Modular Carpet Tile MellowD GT426 EcoFlex NXT (EP) 1236 SY Relaxing Floors Duracolor Trico r Solution Dyed UC Approved NONE NO YES 57.33$ 52.98$ Modular Carpet Tile Metallic Path / QS BT431 EcoFlex NXT (EP) 1236 SY Art Style EcoFlex NXT Solution Dyed UC Approved NONE NO YES 41.11$ 40.12$ Modular Carpet Tile Metalmorphic Plank / QS BT388 EcoFlex NXT (EP) 1236 SY Iconic Earth Colorstrand Solution Dyed Yes NONE NO YES 42.41$ 40.47$ Modular Carpet Tile Micro Bloom GT397 EcoFlex NXT (EP) 1236 SY Lichen Duracolor Trico r Solution Dyed UC Approved NONE NO YES 63.20$ 60.44$ Modular Carpet Tile Mindful / QS / Max Service BT446 EcoFlex Matrix (UZ) 2424 SY Mindful Envirostrand Solution Dyed UC Approved NONE NO NO 18.88$ 15.67$ Modular Carpet Tile Mindful Stripe / QS BT447 EcoFlex Matrix (UZ) 2424 SY Mindful EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 16.72$ 15.67$ Modular Carpet Tile Motivated Movement GT465 EcoFlex NXT (EP) 2424 SY Learn & Live - Taking Steps Duracolor Trico r Solution Dyed Yes NONE NO YES 34.83$ 33.24$ Modular Carpet Tile Mutineer BT366 EcoFlex Matrix (UZ) 2424 SY Renegad e EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 38.07$ 36.68$ DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C Modular Carpet Tile Necessary Action GT467 EcoFlex NXT (EP) 2424 SY Learn & Live - Taking Steps Duracolor Trico r Solution Dyed Yes NONE NO YES 34.83$ 33.24$ Modular Carpet Tile New Basics III / QS BT400 EcoFlex Matrix (UZ) 2424 SY New Basics EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 30.35$ 29.15$ Modular Carpet Tile Off The Wall GT195 EcoFlex NXT (EP) 2424 SY Street Thread Duracolo r Solution Dyed UC Approved NONE NO YES 61.25$ 58.67$ Modular Carpet Tile PDI-Beach Breaker Plank SY020 EcoFlex Air (UW) 1236 SY PDI Tile Colorstrand NONE NO YES 65.21$ 62.23$ Modular Carpet Tile PDI-Beach Breaker Square SY020 EcoFlex Air (UW) 2424 SY PDI Tile Colorstrand NONE NO YES 63.05$ 60.18$ Modular Carpet Tile PDI-Second Wave Plank SY022 EcoFlex Air (UW) 1236 SY PDI Tile Colorstrand NONE NO YES 65.21$ 62.23$ Modular Carpet Tile PDI-Second Wave Square SY022 EcoFlex Air (UW) 2424 SY PDI Tile Colorstrand NONE NO YES 63.05$ 60.18$ Modular Carpet Tile PDI-Shaka Plank SY019 EcoFlex Air (UW) 1236 SY PDI Tile Colorstrand NONE NO YES 54.41$ 51.93$ Modular Carpet Tile PDI-Shaka Square SY019 EcoFlex Air (UW) 2424 SY PDI Tile Colorstrand NONE NO YES 52.25$ 49.87$ Modular Carpet Tile PDI-Special Base Plank (Ripple, Stria, N A EcoFlex Air (UW) 1236 SY PDI Tile Colorstrand NONE NO YES 67.37$ 64.30$ Modular Carpet Tile PDI-Special Base Square (Ripple, Stria, NA EcoFlex Air (UW) 2424 SY PDI Tile Colorstrand NONE NO YES 65.21$ 62.23$ Modular Carpet Tile Photofinish II GT169 EcoFlex NXT (EP) 2424 SY Motorsport II Duracolo r Solution Dyed UC Approved NONE NO YES 60.08$ 57.55$ Modular Carpet Tile Picture This / QS BT334 EcoFlex Matrix (UZ) 2424 SY Mixology EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 22.12$ 20.96$ Modular Carpet Tile Pop Icon GT194 EcoFlex NXT (EP) 2424 SY Street Thread Duracolo r Solution Dyed UC Approved NONE NO YES 61.25$ 58.67$ Modular Carpet Tile Posture / QS BT407 EcoFlex Matrix (UZ) 2424 SY Mixology EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 22.12$ 20.96$ Modular Carpet Tile Proficient / QS GT432 EcoFlex NXT (EP) 1236 SY Learn & Live Duracolor Trico r Solution Dyed UC Approved NONE NO YES 38.88$ 33.98$ Modular Carpet Tile Reawakened Plank GT302 EcoFlex NXT (EP) 1236 SY New Vintag e Duracolor Tricor Solution Dyed UC Approved NONE NO YES 55.06$ 52.71$ Modular Carpet Tile Reckless / QS BT353 EcoFlex Matrix (UZ) 2424 SY Renegad e EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 30.62$ 29.22$ Modular Carpet Tile Reconstruct BT424 EcoFlex NXT (EP) 2424 SY Variant Form EcoFlex NXT Solution Dyed UC Approved NONE NO YES 39.76$ 38.43$ Modular Carpet Tile Rediscovered Plank GT303 EcoFlex NXT (EP) 1236 SY New Vintag e Duracolor Tricor Solution Dyed UC Approved NONE NO YES 55.06$ 52.71$ Modular Carpet Tile Refined Pass / QS BT582 EcoFlex Matrix (UZ) 2424 SY Crossing Curren t Colorstrand Solution Dyed Yes NONE NO YES 29.39$ 28.05$ Modular Carpet Tile Renewed Path / QS / Max Service BT578 EcoFlex Matrix (UZ) 2424 SY Renewed Path Envirostrand Solution Dyed UC Approved NONE NO NO 18.88$ 16.51$ Modular Carpet Tile RestD GT427 EcoFlex NXT (EP) 1236 SY Relaxing Floors Duracolor Trico r Solution Dyed UC Approved NONE NO YES 57.33$ 52.98$ Modular Carpet Tile Restore BT417 EcoFlex Matrix (UZ) 2424 SY Uncharted EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 42.70$ 41.42$ Modular Carpet Tile Riot / QS BT355 EcoFlex Matrix (UZ) 2424 SY Renegad e EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 30.62$ 29.22$ Modular Carpet Tile Rise Up / QS GT420 EcoFlex NXT (EP) 2424 SY Learn & Live Duracolor Trico r Solution Dyed UC Approved NONE NO YES 34.83$ 31.22$ Modular Carpet Tile Rise Up / QS EcoFlex Air GT420 EcoFlex Air (UW) 2424 SY Learn & Live Duracolor Trico r Solution Dyed UC Approved NONE NO YES 41.04$ 31.22$ Modular Carpet Tile River Code GT454 EcoFlex NXT (EP) 1236 SY Data Tide Duracolor Trico r Solution Dyed Yes NONE NO YES 43.00$ 41.04$ Modular Carpet Tile Sabbatical / QS GT433 EcoFlex NXT (EP) 1236 SY Learn & Live Duracolor Trico r Solution Dyed UC Approved NONE NO YES 38.88$ 33.98$ Modular Carpet Tile Sector / QS BT285 EcoFlex Matrix (UZ) 2424 SY Bending Earth EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 32.49$ 32.10$ Modular Carpet Tile Seek Unique / QS BT335 EcoFlex Matrix (UZ) 2424 SY Mixology EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 22.12$ 20.96$ Modular Carpet Tile Seismic Wave Plank GT342 EcoFlex NXT (EP) 1236 SY Expedition Duracolor Trico r Solution Dyed UC Approved NONE NO YES 52.06$ 49.61$ Modular Carpet Tile Selvedge GT179 EcoFlex NXT (EP) 2424 SY Denim Duracolo r Solution Dyed UC Approved NONE NO YES 39.24$ 37.44$ Modular Carpet Tile Shaded Lines / QS BT437 EcoFlex Matrix (UZ) 2424 SY Sketch Effect EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 26.06$ 24.26$ Modular Carpet Tile Shaded Lines / QS EcoFlex Air BT437 EcoFlex Air (UW) 2424 SY Sketch Effect EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 32.65$ 24.26$ Modular Carpet Tile Shared Path / QS BT429 EcoFlex NXT (EP) 1236 SY Art Style EcoFlex NXT Solution Dyed UC Approved NONE NO YES 41.11$ 40.12$ Modular Carpet Tile Shifted Focus GT448 EcoFlex NXT (EP) 1236 SY Optic Reset Duracolor Trico r Solution Dyed UC Approved NONE NO YES 36.77$ 33.07$ Modular Carpet Tile Side Stripe / QS GT419 EcoFlex NXT (EP) 2424 SY Learn & Live Duracolor Trico r Solution Dyed UC Approved NONE NO YES 34.83$ 30.27$ Modular Carpet Tile Side Stripe / QS EcoFlex Air GT419 EcoFlex Air (UW) 2424 SY Learn & Live Duracolor Trico r Solution Dyed UC Approved NONE NO YES 41.04$ 30.27$ Modular Carpet Tile Solve II BT416 EcoFlex Matrix (UZ) 2424 SY Uncharted EcoFlex Matrix Solution Dyed/Yarn Dyed NONE NO YES 42.70$ 41.42$ Modular Carpet Tile Statement Fabric / QS / Max Service BT448 EcoFlex Matrix (UZ) 2424 SY Dexterit y Envirostrand Solution Dyed UC Approved NONE NO NO 18.88$ 17.57$ Modular Carpet Tile Statement Stone / QS BT390 EcoFlex NXT (EP) 2424 SY Iconic Earth Colorstrand Solution Dyed Yes NONE NO YES 38.99$ 37.20$ Modular Carpet Tile Step In Style II / QS GT312 EcoFlex NXT (EP) 2424 SY Tuff Stuff II Duracolo r Solution Dyed UC Approved NONE NO YES 90.11$ 86.47$ Modular Carpet Tile Step Up II / QS GT311 EcoFlex NXT (EP) 2424 SY Tuff Stuff II Duracolo r Solution Dyed UC Approved NONE NO YES 100.30$ 98.87$ Modular Carpet Tile Streetscapes GT308 EcoFlex NXT (EP) 2424 SY On The Scene Duracolor Trico r Solution Dyed UC Approved NONE NO YES 40.66$ 38.80$ Modular Carpet Tile Structured Mesh GT380 EcoFlex NXT (EP) 2424 SY Uncovered Duracolo r Solution Dyed UC Approved NONE NO YES 46.42$ 43.15$ Modular Carpet Tile Super Fresh GT196 EcoFlex NXT (EP) 2424 SY Street Thread Duracolo r Solution Dyed UC Approved NONE NO YES 61.25$ 58.67$ Modular Carpet Tile Swipe Right / QS GT418 EcoFlex NXT (EP) 2424 SY Learn & Live Duracolor Trico r Solution Dyed UC Approved NONE NO YES 34.83$ 30.27$ Modular Carpet Tile Swipe Right / QS EcoFlex Air GT418 EcoFlex Air (UW) 2424 SY Learn & Live Duracolor Trico r Solution Dyed UC Approved NONE NO YES 41.04$ 30.27$ Modular Carpet Tile Tactile Infusion GT422 EcoFlex NXT (EP) 1236 SY Textural Effects Duracolor Trico r Solution Dyed UC Approved NONE NO YES 38.25$ 35.94$ Modular Carpet Tile Taped Off GT197 EcoFlex NXT (EP) 2424 SY Street Thread Duracolo r Solution Dyed UC Approved NONE NO YES 58.39$ 55.92$ Modular Carpet Tile Thematic Thread GT423 EcoFlex NXT (EP) 1236 SY Textural Effects Duracolor Trico r Solution Dyed UC Approved NONE NO YES 38.25$ 35.94$ Modular Carpet Tile Threaded Craft / QS BT414 EcoFlex Matrix (UZ) 2424 SY Artisanal EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 23.56$ 22.49$ Modular Carpet Tile Tonal Shift GT457 EcoFlex NXT (EP) 1236 SY Celebrated Heritag e Duracolor Tricor Solution Dyed Yes NONE NO YES 53.55$ 51.11$ Modular Carpet Tile Tranquil Beauty Plank GT309 EcoFlex NXT (EP) 1236 SY Tranquil Beauty Duracolor Trico r Solution Dyed UC Approved NONE NO YES 50.85$ 48.64$ Modular Carpet Tile Transformative GT324 EcoFlex NXT (EP) 2424 SY Serenit y Duracolor Solution Dyed UC Approved NONE NO YES 57.40$ 54.95$ Modular Carpet Tile Unexpected Texture GT377 EcoFlex NXT (EP) 2424 SY Uncovered Duracolo r Solution Dyed UC Approved NONE NO YES 46.42$ 45.03$ Modular Carpet Tile Urban Canvas GT412 EcoFlex NXT (EP) 1236 SY Nutopia Duracolor Trico r Solution Dyed UC Approved NONE NO YES 49.91$ 47.74$ Modular Carpet Tile Urban Field II GT446 EcoFlex NXT (EP) 1236 SY Nutopia 2.0 Duracolor Trico r Solution Dyed UC Approved NONE NO YES 59.29$ 55.12$ Modular Carpet Tile Urban Fringe II GT445 EcoFlex NXT (EP) 1236 SY Nutopia 2.0 Duracolor Trico r Solution Dyed UC Approved NONE NO YES 59.29$ 55.12$ Modular Carpet Tile Urban Mobility GT430 EcoFlex NXT (EP) 1236 SY Smart Cit y Duracolor Tricor Solution Dyed UC Approved NONE NO YES 59.29$ 55.12$ Modular Carpet Tile Urban Model GT429 EcoFlex NXT (EP) 1236 SY Smart Cit y Duracolor Tricor Solution Dyed UC Approved NONE NO YES 59.29$ 55.12$ Modular Carpet Tile Urban Passage II GT444 EcoFlex NXT (EP) 1236 SY Nutopia 2.0 Duracolor Trico r Solution Dyed UC Approved NONE NO YES 59.29$ 55.12$ Modular Carpet Tile Urban Terrain GT413 EcoFlex Matrix (UZ) 1236 SY Nutopia Matri x Duracolor Tricor Solution Dyed UC Approved NONE NO YES 38.97$ 35.94$ Modular Carpet Tile Urban Transit GT414 EcoFlex Matrix (UZ) 1236 SY Nutopia Matri x Duracolor Tricor Solution Dyed UC Approved NONE NO YES 38.97$ 35.94$ Modular Carpet Tile Venturesome / QS BT356 EcoFlex Matrix (UZ) 2424 SY Renegad e EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 30.62$ 23.22$ Modular Carpet Tile Wavelength GT149 EcoFlex NXT (EP) 2424 SY Power Surg e Duracolor Solution Dyed UC Approved NONE NO YES 54.14$ 51.81$ Modular Carpet Tile Wellbeing GT325 EcoFlex NXT (EP) 2424 SY Serenit y Duracolor Solution Dyed UC Approved NONE NO YES 57.40$ 54.95$ Modular Carpet Tile Write Direction Plank GT318 EcoFlex NXT (EP) 1236 SY Get SmAr t Duracolor Tricor Solution Dyed UC Approved NONE NO YES 44.80$ 42.53$ Modular Carpet Tile Xeric GT406 EcoFlex NXT (EP) 1236 SY Healthy Environments Duracolor Trico r Solution Dyed UC Approved NONE NO YES 45.54$ 43.53$ Modular Carpet Tile X-Factor / QS BT212 EcoFlex Matrix (UZ) 2424 SY X Facto r EcoFlex Matrix Solution Dyed UC Approved NONE NO YES 21.40$ 17.51$ Modular Carpet Tile Zip It Plank GT296 EcoFlex NXT (EP) 1236 SY Denim Duracolo r Solution Dyed UC Approved NONE NO YES 43.11$ 39.10$ LVT Antiek C0015 8" x 60" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 7.18$ 6.01$ LVT Antiek C0015 9" x 48" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 7.18$ 6.01$ LVT Better Togethe r C0097 12" x 36" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 6.46$ 5.60$ LVT Better Togethe r C0097 24" x 24" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 6.46$ 5.60$ LVT Better Togethe r C0097 4" x 36" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 6.46$ 5.60$ LVT Better Togethe r C0097 8" x 48" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 6.46$ 5.60$ LVT Bolde r C0010 36" x 36" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO 6.64$ 6.17$ LVT Centrat o C0104 7.5"x 51.8" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 4.30$ 3.68$ LVT Creative Terrain C0181 18" x 36" SF Creative Terrain PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 10.60$ 10.12$ LVT Edgeland C0085 6" x 48" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 2.68$ 2.36$ LVT Elan Valley C0189 6" x 48" SF Elan Valley PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 2.32$ 2.21$ LVT Grainiac C0013 6" x 48" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 3.76$ 3.05$ LVT Grown U p C0075 9" x 59" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 8.26$ 7.27$ LVT Hemstitch CR710 9.25" x 59.25" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO 8.44$ 8.14$ LVT Hit the Mar k C0095 12" x 24" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 7.90$ 6.71$ LVT Hit the Mar k C0095 18" x 36" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 7.90$ 6.71$ LVT Hit the Mar k C0095 7.25" x 48" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 7.90$ 6.71$ LVT Large & Local Reforestatio n C0188 9" x 59" SF Large & Local PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 5.56$ 5.31$ LVT Large & Local Rendered Fla x C0192 9" x 59" SF Large & Local PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 5.56$ 5.31$ LVT Large & Local Rugged Foundatio n C0191 9" x 59" SF Large & Local PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 5.56$ 5.31$ LVT Large & Local Wood C0128 9" x 59" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 5.56$ 4.80$ LVT Lineate C0089 9" x 59" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO 6.64$ 6.17$ LVT Linked CR708 9.84" x 39.37" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO 8.44$ 8.14$ LVT Living Local Chromascope C0159 12" x 24" SF Living Local PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 4.48$ 4.27$ LVT Living Local Optic Hues C0178 12" x 24" SF Living Local PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 4.48$ 4.27$ LVT Living Local Premium Woods C0194 7.72" x 51.97" SF Living Local PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 4.48$ 4.27$ LVT Living Local Stoneworks C0179 12" x 24" SF Living Local PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 4.48$ 4.27$ LVT Living Local Terrazzo C0180 12" x 24" SF Living Local PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 4.48$ 4.27$ LVT Living Local Wood Glue Down C2039 6" x 48" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 4.48$ 3.68$ LVT Matuto Plus C0135 12" x 24" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 5.74$ 4.94$ LVT Metal C0059 18" x 36" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 8.26$ 7.27$ LVT Mixte Solid C0090 36" x 36" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO 6.64$ 6.17$ LVT Mixte Stripe C0091 36" x 36" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO 6.64$ 6.17$ LVT Molveno Stones C0109 11.75" x 35.75" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 7.00$ 5.72$ LVT Molveno Woods C0110 7.75" x 59.75" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 7.00$ 5.72$ DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C LVT Morikato Wood C0016 7" x 48" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 6.46$ 5.83$ LVT Neches Bend C0187 7.52"x 51.8" SF Dodford 1 2 PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 4.48$ 4.27$ LVT Second Home Wood C0141 7.5" x 48" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 6.64$ 5.50$ LVT Secoya C0009 9" x 59" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO 6.46$ 6.17$ LVT Select Step II Stone CR704 18" x 36" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 2.14$ 2.04$ LVT Select Step II Wood CR703 7.25" x 48" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO 2.14$ 2.04$ LVT Urban Native Ston e C0084 12" x 24" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 3.04$ 2.56$ LVT Urban Native Wood C0083 8" x 48" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES 3.04$ 2.56$ LVT Vivid Step Plank CR70 5 6" x 48" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO 2.68$ 2.10$ LVT Vivid Step Stone CR706 12" x 24" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO 2.68$ 2.10$ LVT Weave CR709 18" x 36" SF PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO 8.44$ 8.14$ Rubber Tile TRUE Hammere d TRMB 17-13/16" x 17 - SF TRUE NONE *Antimicrobial free for production after 7/1/19 NO NO 16.31$ 15.57$ Rubber Tile TRUE Hammere d TRMB 35-11/16" x 35 - SF TRUE NONE *Antimicrobial free for production after 7/1/19 NO NO 15.80$ 15.08$ Rubber Sheet TRUE Medi-Flex Sheet 2mm TRS2B 5' x 50' nominal SF NONE *Antimicrobial free for production after 7/1/19 NO NO 9.72$ 7.99$ Rubber Sheet TRUE Medi-Flex Sheet 3mm TRS3B 5' x 50' nominal SF NONE *Antimicrobial free for production after 7/1/19 NO NO 12.10$ 10.01$ Rubber Tile TRUE Medi-Flex Tile 2mm TRSTB 17-13/16" x 17 - SF NONE *Antimicrobial free for production after 7/1/19 NO NO 12.83$ 10.84$ Rubber Tile TRUE Medi-Flex Tile 2mm TRSTB 35-11/16" x 35 - SF NONE *Antimicrobial free for production after 7/1/19 NO NO 12.53$ 10.84$ Rubber Tile TRUE Medi-Flex Tile 3mm TRSIB 17-13/16" x 17 - SF NONE *Antimicrobial free for production after 7/1/19 NO NO 15.53$ 13.48$ Rubber Tile TRUE Medi-Flex Tile 3mm TRSIB 35-11/16" x 35 - SF NONE *Antimicrobial free for production after 7/1/19 NO NO 15.28$ 13.48$ Rubber Tile TRUE Round TRRB 35-1/2" x 35-1/2 " SF TRUE NONE *Antimicrobial free for production after 7/1/19 NO NO 15.28$ 14.58$ Rubber Tile TRUE Round TRRB 17-11/16" x 17 - SF TRUE NONE *Antimicrobial free for production after 7/1/19 NO NO 15.80$ 15.08$ Resilient Sheet Geomorphi c C2044/C2045 6' & 12' Width SY Healthy Environments PVC, Ortho-Phthalate Free NO YES 41.38$ 37.40$ Resilient Sheet Juniperus C2042/C204 3 6' & 12' Width SY Healthy Environments PVC, Ortho-Phthalate Free NO YES 41.38$ 36.68$ Resilient Sheet Klei Firma C2046/C204 7 6' & 12' Width SY Healthy Environments PVC, Ortho-Phthalate Free NO YES 41.38$ 36.68$ Resilient Sheet Sisalana C2040/C2041 6' & 12' Width SY Healthy Environments PVC, Ortho-Phthalate Free NO YES 41.38$ 36.68$ Resilient Sheet Living Kind C2049 13'2" Width SY Living Kind PVC, Ortho-Phthalate Free NO YES 19.78$ 16.59$ Resilient Sheet Calmness C2023 6' & 12' Width SY Serenit y PVC, Ortho-Phthalate Free NO YES 41.38$ 36.68$ Resilient Sheet Ephemeral C2022 6' & 12' Width SY Serenit y PVC, Ortho-Phthalate Free NO YES 41.38$ 36.68$ Resilient Sheet Sensor y C2021 6' & 12' Width SY Serenit y PVC, Ortho-Phthalate Free NO YES 41.38$ 36.68$ Resilient Sheet Therapeuti c C2020 6' & 12' Width SY Serenit y PVC, Ortho-Phthalate Free NO YES 41.38$ 36.68$ Resilient Sheet Medella C2048 6' 6" Width SY Healthy Environments PVC, Ortho-Phthalate Free NO YES 48.04$ 40.69$ Hardwood / Laminate Voxwood C0182 54.33" Length SF RevWood Contrac t Formaldehyde NO NO 5.74$ 5.48$ Adhesives Nubroadlok (LifeLoc) Moisture Proof Latex Seam LLSSB 112.26$ Adhesives NuBroadlok Premium Plu s B0020 44.90$
Adhesives NuBroadlok Premium Plu s B0020 44.90$
Adhesives NuBroadlok VRT B0030 75.21$
Adhesives NuBroadlo k B261 19.08$
Adhesives NuBroadlo k B267 117.87$
Adhesives EnPress M004C 112.26$
Adhesives FlexLok FLXTB 101.03$
Adhesives OptiSeal M003B 151.55$
Adhesives PrimeCoa t XL23C 44.90$
Adhesives M700 VA67C 39.28$
Adhesives M700 VA67C 140.33$
Adhesives M95.0 M95C 50.51$
Adhesives M95.0 M95C 157.17$
Adhesives MS160 MS160 190.85$
Adhesives SurfaceSeal XL26C 106.65$
Adhesives M99.0 M99 56.12$
Adhesives M99.0 M99 190.85$
Adhesives AD 590 AD590 151.55$
Adhesives AD 777 AWP77 72.96$
Adhesives AD 777 AWP77 224.53$
Adhesives Zip Step Tape ADZIP 246.98$
Adhesives Infuze Seam Seale r INFZC 6.73$
Adhesives M45 M45C 5.26$
Accessories - Rubber AD888 AD888-01 318.84$
Accessories - Rubber AD888 AD888-02 5.60$
Accessories - Rubber AD888 AD888-03 70.72$
Accessories - Rubber Dual Cartridge Gun LOCDC 136.96$
Accessories - Rubber Durabond Package LOCPC 154.92$
Accessories - Rubber TRUE Weld Rod TRWB 93.17$
Accessories - Rubber Visual Strip - Black VITC-22 83.07$ Accessories - Rubber Visual Strip - Night Glow VITC-82 150.43$ Accessories - Rubber Visual Strip - Red VITC-52 104.40$ Accessories - Rubber Visual Strip - White VITC-18 104.40$ Accessories - Rubber Visual Strip - Yellow VITC-72 104.40$ Accessories - Rubber Square Mix Nozzles (10 pack) LOCNC 30.30$ Accessories - Rubber Chemical Weld Cartridge-Loctite LOCHC 34.79$ Accessories - Sheet Infuze Seam Seale r INFZC 6.73$
Accessories - Sheet Heterogeneous Sheet Vinyl Weld Rod s WELDC 40.41$ Accessories - Sheet Homogeneous Sheet Vinyl Weld Rod s MWRC 40.41$ Accessories - LVT AccuSound VU01C 0.55$
Accessories - LVT ActiveSound VU02C 0.77$
Accessories - LVT Scratch Repair Ki t VA8C-1 57.25$
Accessories - LVT Scratch Repair Ki t VA8C-3 147.06$
Accessories - HVT Homogeneous Vinyl Tile Weld Rods CTWR 168.39$ Accessories - HVT Deep Scrub Cleane r HVTDC 0.01$
Accessories - HVT Deep Scrub Pad (maroon ) HVTDP 0.01$
Accessories - HVT Initial Surface Cleane r HVTSC 0.01$
Accessories - RevWood Contract Initial Surface Cleaner Pad (natural) HVTSP 0.01$ #REF! Installation Kit LT4C 28.06$
Accessories - RevWood Contract Instamatch Repair Kit IM 40.41$ Accessories - RevWood Contract Unifix Repair Tool UT 127.98$ Accessories - Stair Tread Hammered, Tread Onl y RTM 16.83$ Accessories - Stair Tread Hammered, With Rise r OPM 20.20$ Accessories - Stair Tread Hammered, With Riser & Visual Stri p OVM 23.57$ Accessories - Stair Tread Hammered, With Visual Stri p RVM 21.32$ Accessories - Stair Tread Round, Tread Onl y TRNB 16.83$ Accessories - Stair Tread Round, With Rise r TROB 20.20$ Accessories - Stair Tread Round, With Riser & Visual Strip TRQB 23.57$ Accessories - Stair Tread Round, With Visual Strip TRPB 21.32$ Wall Base - Rubber Straight Wall Base - 120' Rolls CRW01 0.89$ Wall Base - Rubber Straight Wall Base - 96' Rolls CRW01 1.54$ Wall Base - Rubber Straight Wall Base - 120' Rolls CRW02 0.89$ Wall Base - Rubber Straight Wall Base - 96' Rolls CRW02 1.54$ Wall Base - Rubber Coved Wall Base - 120' Rolls CRW03 0.89$ Wall Base - Rubber Coved Wall Base - 96' Rolls CRW03 1.54$ Wall Base - Rubber CovedWall Base - 120' Rolls CRW05 0.89$ Wall Base - Rubber Coved Wall Base - 96' Rolls CRW05 1.54$ Wall Base - Vinyl Straight Wall Base - 120' Rolls CVW01 0.83$ Wall Base - Vinyl Straight Wall Base - 96' Rolls CVW01 1.40$ Wall Base - Vinyl Straight Wall Base - 120' Rolls CVW02 0.83$ Wall Base - Vinyl Straight Wall Base - 96' Rolls CVW02 1.40$ Wall Base - Vinyl Straight Wall Base - 120' Rolls CVW03 0.83$ Wall Base - Vinyl Straight Wall Base - 96' Rolls CVW03 1.40$ Wall Base - Vinyl Straight Wall Base - 120' Rolls CVW04 0.83$ DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C Wall Base - Vinyl Straight Wall Base - 96' Rolls CVW04 1.40$ Wall Base - Vinyl Straight Wall Base - 120' Rolls CVW05 0.76$ Accessories - Stair Tread Hammered Tread CRS01 16.74$ Accessories - Stair Tread Hammered Tread CRS01 16.74$ Accessories - Stair Tread Hammered Tread & Riser CRS02 20.08$ Accessories - Stair Tread Hammered Tread & Riser CRS02 20.08$ Accessories - Stair Tread Hammered Tread w/Vis Strip CRS03 20.61$ Accessories - Stair Tread Hammered Tread w/Vis Strip CRS03 20.61$ Accessories - Stair Tread Hammered Tread & Riser w/VisStri p CRS02 23.96$ Accessories - Stair Tread Hammered Tread & Riser w/VisStri p CRS03 23.96$ Accessories - Stair Tread Round Tread CRS03 16.74$
Accessories - Stair Tread Round Tread CRS04 16.74$
Accessories - Stair Tread Round Tread & Riser CRS04 20.08$ Accessories - Stair Tread Round Tread & Riser CRS05 20.08$ Accessories - Stair Tread Round Tread w/Vis Strip CRS05 20.61$ Accessories - Stair Tread Round Tread w/Vis Strip CRS06 20.61$ Accessories - Stair Tread Round Tread & Riser CRS06 23.96$ Accessories - Stair Tread Round Tread w/Vis Strip CRS07 23.96$ Accessories - Stair Tread Round Tread w/Vis Strip CRS07 5.83$ Accessories - Stair Tread Round Tread & Riser w/VisStri p CRS08 8.89$ Accessories - Stair Tread Round Tread & Riser w/VisStri p CRS08 1.85$ Accessories - Stair Tread Stringer / Rise r CRS09 1.10$ Accessories - Stair Tread Smooth Landing Tile CRS10 2.03$ Accessories - Rubber Universal Transition - Finish material to finish CRA01 1.19$ Accessories - Rubber Universal Transition - Finish material to finish CRA02 1.73$ Accessories - Rubber Universal Transition - Finish material to finish CRA03 1.54$ Accessories - Rubber T-Moulding Track Pinless Metal Track (12ft) CRA04 1.67$ Accessories - Rubber Adaptors - Finish material to finish material 1/8" CRA05 1.81$ Accessories - Rubber Adaptors - Finish material to finish material 1/8" Tile- CRA06 0.86$ Accessories - Rubber Reducers - Finish material to floor 1/8" Underslung CRA07 1.54$ Accessories - Rubber Reducers - Finish material to floor 1/4" Underslung CRA08 0.93$ Accessories - Rubber Reducers - Finish material to floor 1/8" Reducer CRA09 3.98$ Accessories - Rubber Reducers - Finish material to floor 1/4" Reducer CRA10 5.28$ Accessories - Rubber Stair Installation Cove Stick (Natural Color Only - CRA11 2.69$ Accessories - Rubber Stair Nose to Flooring 1/8" Stair Nosing (12ft) CRS11 2.86$ Accessories - Rubber Stair Nose to Flooring 1/4" Undercut Nosing (12ft) CRS12 2.89$ Wall Base - Rubber Architectural Base - Straight Cut 8' Lengths AWB01 2.63$ Wall Base - Rubber Architectural Base - Straight Cut 8' Lengths AWB01 2.82$ DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C SUPPLIER: UOM
New York Region 1:
Bronx, Queens, Kings,
Richmond, Nassau,
Suffolk, Putnam,
Westchester & Orange
Counties
New York Region 2:
Erie, Niagara, St.
Lawrence, Franklin,
Essex, Jefferson, Lewis,
& Hamilton Counties
New York Region 3:
Remainder of State of
New York
Labor Description Labor Rate Labor Rate Labor Rate Non Union RateUnion Wage RateNon Union RateUnion Wage RateNon Union RateUnion Wage RateNon Union RateUnion Wage RateNon Union RateUnion Wage RateNon Union RateUnion Wage Rate Monday - Friday Standard 8 Hour Shift - Hourly Labor Rate for Flooring Contract Labor Services Not Listed HR $168.03 $168.03 $124.48 $124.48 $168.03 $82.23 $111.02 $82.23 $111.02 $82.23 $111.02 $101.20 $136.64 Open Market Open Market Monday - Friday Overtime - Add SY $6.12 $6.12 $4.88 $4.88 $6.12 $3.81 $4.78 $3.81 $4.78 $3.81 $4.78 $4.83 $6.05 Open Market Open Market Saturday - Add SY $6.12 $6.12 $4.88 $4.88 $6.12 $3.81 $4.78 $3.81 $4.78 $3.81 $4.78 $4.83 $6.05 Open Market Open Market Sunday & Holiday - Add SY $9.17 $9.17 $7.34 $7.34 $9.17 $5.73 $7.16 $5.73 $7.16 $5.73 $7.16 $7.27 $9.07 Open Market Open Market Installation Broadloom (direct glue down) SY $14.84 $14.84 $10.99 $10.99 $14.84 $7.85 $10.61 $8.46 $11.42 $8.46 $11.42 $10.86 $14.65 Open Market Open Market Installation Broadloom (direct glue down w/ pattern)SY $15.65 $15.65 $11.59 $11.59 $15.65 $8.46 $11.42 $9.06 $12.23 $9.06 $12.23 $11.46 $15.46 Open Market Open Market Installation Carpet Tile SY $12.81 $12.81 $9.50 $9.50 $12.81 $6.71 $9.06 $7.34 $9.91 $7.34 $9.91 $9.01 $11.26 Open Market Open Market Removal of Double Stick Installation SY $13.19 $13.19 $9.77 $9.77 $13.19 $7.24 $9.79 $7.24 $9.79 $7.24 $9.79 $9.66 $13.05 Open Market Open Market Removal of Broadloom (direct glue down) SY $6.69 $6.69 $4.96 $4.96 $6.69 $3.62 $4.90 $3.62 $4.90 $3.62 $4.90 $4.84 $6.52 Open Market Open Market Removal of Carpet Tile SY $6.41 $6.41 $4.74 $4.74 $6.41 $3.62 $4.90 $3.62 $4.90 $3.62 $4.90 $4.43 $5.99 Open Market Open Market Removal/Disposal Resilient Flooring SF $2.14 $2.14 $1.58 $1.58 $2.14 $1.27 $1.71 $1.46 $1.98 $1.46 $1.98 $1.46 $1.98 Open Market Open Market Carpet Disposal SY $1.71 $1.71 $1.27 $1.27 $1.71 $0.88 $1.21 $1.11 $1.49 $1.11 $1.49 $1.13 $1.53 Open Market Open Market Broadloom or Carpet Tile Reclamation Fee SY $3.85 $3.85 $2.85 $2.85 $3.85 $2.53 $3.42 $2.65 $3.59 $2.65 $3.59 $2.65 $3.59 Open Market Open Market Installation of VCT SF $2.98 $2.98 $2.22 $2.22 $2.98 $1.42 $1.92 $1.54 $2.08 $1.54 $2.08 $1.89 $2.56 Open Market Open Market Installation of Luxury Vinyl Tile (Planks or Squares)SF $4.08 $4.08 $3.03 $3.03 $4.08 $1.89 $2.56 $2.22 $2.98 $2.22 $2.98 $2.85 $3.85 Open Market Open Market Installation of Laminate (Planks or Squares) SF $4.18 $4.18 $3.10 $3.10 $4.18 $2.28 $2.91 $2.40 $3.16 $2.40 $3.16 $3.03 $4.12 Open Market Open Market Installation of Rubber Tile SF $4.45 $4.45 $3.55 $3.55 $4.45 $2.41 $3.27 $2.54 $3.44 $2.54 $3.44 $3.27 $4.41 Open Market Open Market Installation of Rubber Roll SF $8.21 $8.21 $6.57 $6.57 $8.21 $4.72 $5.90 $4.96 $6.21 $4.96 $6.21 $6.36 $7.96 Open Market Open Market Installation of Sheet Vinyl SY $30.77 $30.77 $22.80 $22.80 $30.77 $19.61 $26.49 $19.61 $26.49 $19.61 $26.49 $22.63 $30.57 Open Market Open Market Heat Welding (Sheet Vinyl) LF $6.10 $6.10 $4.52 $4.52 $6.10 $3.81 $5.13 $3.93 $5.30 $3.93 $5.30 $4.41 $5.96 Open Market Open Market Installation Flash cove (Sheet Vinyl/Rubber Roll-excludes metal finish piece) LF $15.64 $15.64 $11.59 $11.59 $15.64 $8.13 $10.97 $9.06 $12.23 $9.06 $12.23 $11.47 $15.49 Open Market Open Market Engineered Hardwood Flooring Glue Down Installation over Concrete standard straight lay (includes equipment for dust collection and protective gear) SF $15.58 $15.58 $10.12 $10.12 $15.58 $8.04 $12.37 $8.23 $12.65 $8.23 $12.65 $9.80 $15.08 Open Market Open Market Palletize/Shrink Wrap old carpet for reclamationSY $3.42 $3.42 $2.53 $2.53 $3.42 $1.89 $2.56 $2.22 $2.98 $2.22 $2.98 $2.22 $2.98 Open Market Open Market Conventional Furniture Moving (Light) SY $5.87 $5.87 $4.35 $4.35 $5.87 $3.62 $4.90 $3.62 $4.90 $3.62 $4.90 $4.23 $5.71 Open Market Open Market Conventional Furniture Moving (Medium) SY $7.49 $7.49 $5.55 $5.55 $7.49 $4.84 $6.52 $4.84 $6.52 $4.84 $6.52 $5.44 $7.34 Open Market Open Market L I F T Systems / Carpet Tile Projects Only - Add SY $21.66 $21.66 $16.05 $16.05 $21.66 $13.63 $18.41 $14.86 $20.06 $14.86 $20.06 $16.05 $21.66 Open Market Open Market Moisture Testing EA $341.57 $341.57 $253.02 $253.02 $341.57 $189.76 $256.17 $221.40 $298.88 $221.40 $298.88 $221.40 $298.88 Open Market Open Market Night / Saturday Labor - Add SY $6.12 $6.12 $4.88 $4.88 $6.12 $3.56 $4.46 $3.81 $4.78 $3.81 $4.78 $4.83 $6.05 Open Market Open Market Sunday / Holiday Labor - Add SY $9.17 $9.17 $7.34 $7.34 $9.17 $5.35 $6.69 $5.73 $7.16 $5.73 $7.16 $7.27 $9.07 Open Market Open Market Install Base LF $4.92 $4.92 $3.47 $3.47 $4.92 $2.53 $3.63 $2.53 $3.63 $2.53 $3.63 $3.30 $4.68 Open Market Open Market Furnish / Install Base, Std. 4-Inch Vinyl/Rubber Blend, Black/Brown LF $5.55 $5.55 $4.10 $4.10 $5.55 $3.16 $4.26 $3.16 $4.26 $3.16 $4.26 $3.93 $5.31 Open Market Open Market Furnish / Install Base, Std. 6-Inch Vinyl/Rubber Blend, Black/Brown LF $6.51 $6.51 $4.83 $4.83 $6.51 $3.71 $5.02 $3.71 $5.02 $3.71 $5.02 $4.63 $6.24 Open Market Open Market Furnish / Install Transition, Standard,
Black/Brown/Gold/Silver LF $6.83 $6.83 $5.05 $5.05 $6.83 $3.79 $5.10 $3.79 $5.10 $3.79 $5.10 $4.86 $6.55 Open Market Open Market Furnish / Install Ceramic Tile SF $63.80 $63.80 $47.26 $47.26 $63.80 $36.75 $49.62 $36.75 $49.62 $36.75 $49.62 $47.26 $63.78 Open Market Open Market Floor Prep - Skim Coating to 1/8 Inch (Labor and Portland Based Material. Excludes leveling.) SF $2.98 $2.98 $2.22 $2.22 $2.98 $1.52 $2.05 $1.77 $2.39 $1.77 $2.39 $1.89 $2.56 Open Market Open Market Hourly Labor Rate for Flooring Contract Labor Services not Listed HR $168.03 $168.03 $124.48 $124.48 $168.03 $63.25 $85.39 $82.23 $111.02 $82.23 $111.02 $101.20 $136.64 Open Market Open Market Supplemental Benefits HR $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 Open Market Open Market Project Management Fee is included if labor is provided directly by MohawkONE Open Market Open Market
LABOR NOTES:
Labor prices are not to exceed prices and are effective 4/15/21.
Installation of floor coverings are for direct glue down installation and include installation of floor covering and minor floor prep, defined as filling of minor gaps and voids no larger than 1/8"x1/8" and sweeping and are based on a clean and clear floor.
Other services and ancillary items are available through Mohawk. These services are quoted job by job and negotiated between Mohawk and the customer.
Ceramic tile material pricing includes standard profile tile product suitable for light to medium indoor commercial applications.
Additional charges may apply for Fingerprinting and Background Checks.
Labor quoted job by job for Alaska, Hawaii, American Samoa, Federated States of Micronesia, Guam, Midway Islands, Northern Marina Islands, Puerto Rico, and U.S. Virgin Islands.
LABOR EXCLUSIONS:
Asbestos Testing and Abatement
Border Labor
Carpet Cleaning
Ceramic tile furnish and install, in addition to other stated exclusions herein, excludes accessories, trim pieces, specialty tiles, moisture membranes, flashing, wet area installations, setting materials, grout, transitions, freight and fuel surcharges Cleaning, sanding, refinishing, or sealing of new flooring Non-Continental:
AK & HI
West
CA, CO, HI, AK, NV, NM, OR, WA, WY,
MT, ID, SD, ND, UT
South:
AR, AZ, TX, LA, MS
Southeast Region:
AL, FL, GA, KY, NC, SC,
Northeast Region:
MA, ME, VT, NH, CT, RI, PA, VA, DC, RI,
MD, DE, NJ
Central:
KS, OH, MI, MN, WI, MO, OK, MS, NE,
IA, PA, IL, IN
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C Delivery/Handling to job site from installer warehouse
Disposal of Existing Hard Tile Flooring
Dumpster Charges
Excessive trip charges and/or small job charges less than 200sy or 1,800sf per trade Excessive cutting/trimming/sanding/staining of hardwood/flooring for custom pattern work Extensive floor exceeding the above described floor prep Furniture Moving (high density or extraordinary)
Hoisting
Material, adhesive, pad, underlayment, base inside corners, base outside corners, entry mats, felt paper, rosin paper, moldings, plywood, solid wood planks or sleepers, vapor retarder, unless otherwise noted.
Millwork/trim/transition/quarter round/wood base for completion of hardwood installation Moisture Remediation/Abatement
Moving of computers, telephony, equipment, or personal items Pattern match labor or custom pattern labor, unless otherwise noted Payment and Performance Insurance Bonds
Phasing Labor
Protection of Floors
Reclamation Government Imposed Fees are Excluded wherever applicable.
Reclamation fee excludes packaging, palletization, and shipment to reclamation processor Removal/disposal of floorings other than quoted above
Sales Tax - Local, State, and Federal
Stair Labor
Storage of Materials long-term
Transitions exclude Schluter or similar needed for ceramic tile installation Union upcharges
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 14 of 17
EXHIBIT “B”
INSURANCE PROVISIONS
Including
Verification of Coverage,
Sufficiency of Insurers,
Errors and Omissions Coverage,
Minimum Scope of Insurance,
Deductibles and Self-Insured Retentions, and
Severability of Interests (Separation of Insureds)
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 15 of 17
INSURANCE
1. Procurement and Maintenance of Insurance. Contractor shall procure and maintain public liability and property damage insurance against all claims for injuries against persons or damages to property resulting from Contractor’s performance under this Agreement.
Contractor shall procure and maintain all insuranc e at its sole cost and expense, in a form and content satisfactory to the City, and submit concurrently with its execution of this Agreement .
Contractor shall also carry workers’ compensation insurance in accordance w ith California workers’ compensation l aws. Such insurance shall be kept in full force and effect during the term of this Agreement , including any extensions. Such insurance shall not be cancela ble without thirty (30) days advance written notice to City of any proposed cancellation. Certificates of insurance evidencing the foregoing and designating the City, its elected officials, officers, employees, agents, and volunteers as additional named i nsureds by blanket shall be delivered to and approved by City prior to commencement of services. The procuring of such insuran ce certificates, and endorsements evidencing the same shall not be construed as a limitation of Contractor’s obligation to indemn ify City, its elected officials, officers, agents, employees, and volunteers.
2. Minimum Scope of Insurance. The minimum amount of insurance requir ed under this Agreement shall be as follows:
1. Comprehensive general liability and personal injury with limits of at least one million dollars ($1,000,000.00) combin ed single limit coverage per occurrenc e and two million dollars ($2,000,000) general aggregate;
2. Automobile liability insurance with limits of at least one million dollars ($1,000,000.00) per occurrence;
3. Professional liability (errors and omissions) insurance with limits of at least one million dollars ($1,000,000.00) per occurrence and two million dollars ($2,000,000) annual aggregate is:
_________ required
____X_____ is not required;
4. Workers’ Compensation insurance in the statutory amount as re quired by the State of California and Employer’s Liability Insurance with limits of at least one million dollars $1 million per occurrence. If Contractor has no employees, Contractor shall complete the City’s Request for Waiver of Workers’ Compensation Insurance Requirement form.
3. Primary Insurance. For any claims related to this Agreement, Contractor’s insurance coverage shall be primary with respect to the City and its respective elected offi cials, officers, employees, agents, and volunteers. Any insu rance or self-insurance maintained by City and its respective elected officials, officers, employees, agents, and volunteers shall be in excess of Contractor’s insurance and shall not contribute with it. For Workers’ Compensation and Employer’s Liability Insurance only, the insurer shall waiv e all rights of subrogation and DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 16 of 17
contribution it may have against City, its elected officials, officers, employees, agents, and volunteers.
5. Sufficiency of Insurers. Insurance required in this Agreement shall be prov ided by authorized insurers in good standing with the State of California. Coverage shall be provided by insurers admitted in the State of California with an A.M. Best’s Key Rating of B++, Clas s VII, or better, unless otherwise acceptable to the City.
6. Verification of Coverage. Contractor shall furnish City with both certificates of insurance and blanket endorsements, including blanket additional insured endorsements, affecting all of the cov erages required by this Agreement. The certificates are to be signed by a person authorized by that insurer to bind coverage on its behalf. All proof of insurance is to be received and approved by the City before work commences. City reserves the right to require Contractor’s insurers to provide complete. Additional insured endorsements are not requi red for Errors and Omissions and Workers’ Compensation policies.
Verification of Insurance coverage may be provided by: (1) an approved General and/or Auto Liability Endorsement Form for the City of Palm Springs or (2) an acceptable Certificate of Liability Insurance Coverage with an approved Additional Insured Endorsement with the following endorsements stated on the certificate:
A. "The City of Palm Springs, its officials, employees, and agents are included as an additional insured…” ("as respects City of Palm Springs Contract No.___" or "for any and all work performed with the City" may be included in this statement).
B. "This insurance is primary and no n-contributory over any insurance or self - insurance the City may have..." ("as respects City of Palm Springs Contract No.___" or "for any and all work performed with the City" may be included in this statement).
C. "Should any of the above-described policies be canceled before the expiration date thereof, the issuin g company will mail 30 days written no tice to the Certificate Holder named." Language such as, “endeavor to” mail and "but failure to mail such notice shall impose no obligation or liability of any kind upon the company, its agents or representative" is no t acceptable and must be crossed out.
D. Both the Workers’ Compensation and Employers' Liability policies shall contain the insurer's waiver of subrogation in favor of City, its elected officia ls, officers, employees, agents, and volunteers.
In addition to the endorsements listed above, the City of Palm Springs shall be named the certificate holder on the policies.
All certificates of insurance and endorsements are to be received and approved by the City before work commences. All certificates of insura nce must be authorized by a person wit h authority to bind coverage, whether that is the authorized agent/broker or insurance underwriter.
Failure to obtain the required documents prior to the c ommencement of work shall not waive the Contractor’s obligation to provide them.
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 55575.00001\40098778.2
Revised 2.9.22 Page 17 of 17
7. Deductibles and Self-Insured Retentions. Contractor guarantees payment of all deductibles and self-insured retentions.
8. Severability of Interests (Separation of Insu reds). This insurance applies separately to each insured agai nst whom claim is made or suit is brou ght except with respect to the limits of the insurer’s liability.
DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C