Palm Springs City Council
May 12, 2026

ATTACHMENT B
CONTRACT SERVICES AGREEMENT 26P039

CONTRACT SERVICES AGREEMENT 26P039

PREBOOKING AND RESERVATION SYSTEM FOR PARCS

THIS AGREEMENT FOR CONTRACT SERVICES (“Agreement”) is made and entered into on April ___, 2026, by and between the City of Palm Springs , a California charter city and municipal corporation (“City”), and Skidata, Inc, a Delaware Corporation (“Contractor”). City and Contractor are individually referred to as “Party” and are collectively referred to as the “Parties”.

RECITALS

A. City requires the services of a contractor, for an integrated prebooking and reservation system, (“Project”).

B. Contractor has submitted to City a proposal to provide an integrated prebooking and reservation system to run the Parking Access and Revenue Control System for Palm Springs International Airport, under the terms of this Agreement.

C. Contractor is qualified by virtue of its experience, training, education, reputation, and expertise to provide these services and has agreed to provide such services as provided in this Agreement.

D. City desires to retain Contractor to provide such contract services.

NOW, THEREFORE, in consideration of the promises and mutual obligations, covenants, and conditions contained herein, and other valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties agree as follows:

AGREEMENT

1. SERVICES OF CONTRACTOR

1.1 Scope of Services. In compliance with all terms and conditions of this Agreement, Contractor agrees to perform the contract services set forth in the Scope of Services described in Exhibit “A” (the “Services” or “Work”), which is attached and incorporated herein by this reference. As a material inducement to the City entering into this Agreement, Contractor represents and warrants that Contractor is a provider of first class work and contract services and that Contractor is experienced in performing the Work contemplated and, in light of such status and experience, Contractor covenants that it shall perform the Work in a competent, professional, and satisfactory manner consistent with the level of care and skill ordinarily exercised by high quality, ex perienced, and well qualified members of the profession currently practicing under similar conditions.

1.2 Contract Documents. The Agreement between the Parties shall consist of the following: (1) this Agreement; (2) the Scope of Services; (3) the City’s Request for Proposals; and, (4) the Contractor’s signed, original proposal submitted to the City (“Contractor’s Proposal”), (collectively referred to as the “Contract Documents”). The City’s Request for Proposals and the Contractor’s Schedule of Compensation, which is attached as Exhibits “B” is incorporated herein by this reference and are made a part of this Agreement. The Scope of Services shall include

the Contractor’s Proposal. All provisions of the Scope of Services, the City’s Request for Proposals and the Contractor’s Proposal shall be binding on the Parties. Should any conflict or inconsistency exist in the Contract Documents, the conflict or inconsistency shall be resolved by applying the provisions in the highest priority document, which shall be determined in the following order of priority: (1 st) the provisions of the Scope of Services (Exhibit “A”); (2 nd) the provisions of the City’s Request for Proposal; (3 rd) the terms of this Agreement; and, (4 th) the provisions of the Contractor’s Proposal.

1.3 Compliance with Law. Contractor warrants that all Services rendered shall be performed in accordance with all applicable federal, state, and local laws, statutes, ordinances lawful orders, rules, and regulations. Contractor shall be liable for all violations of such laws and regulations in connection with the Services and this Agreement.

1.4 Licenses, Permits, Fees, and Assessments. Contractor represents and warrants to City that it has obtained all licenses, permits, qualifications, and approvals of whatever nature that are legally required to practice its profession and perform the Work and Services required by this Agreement. Contractor represents and warrants to City that Contractor shall, at its sole cost and expense, keep in effect at all times during the term of this Agreement, any license, permit, qualification, or approval that is legally required for Contractor to perform the Work and Services under this Agreement.

1.5 Familiarity with Work. By executing this Agreement, Contractor warrants that Contractor (a) has thoroughly investigated and considered the Scope of Services to be performed, (b) has carefully considered how the Services should be performed, and (c) fully understands the facilities, difficulties, and restrictions attending performance of the Services under this Agreement.

If the Services involve work upon any site, Contractor warrants that Contractor has or will investigate the site and is or will be fully acquainted with the conditions there existing, prior to commencement of any Services. Should the Contractor discover any latent or unknown conditions that will materially affect the performance of the Services, Contractor shall immediately inform the City of such fact and shall not proceed except at Contractor's risk until written instructions are received from the City.

2. COMPENSATION

2.1 Maximum Contract Amount. For the Services rendered under this Agreement, Contractor shall be compensated by City in accordance with the Schedule of Compensation, which is attached as Exhibit “B” and incorporated in this Agreement by reference. Compensation shall not exceed the maximum contract amount of forty three thousand seven hundred eighty dollars and zero cents ($43,780.00) ("Maximum Contract Amount"), except as may be provided under Section 2.3. The method of compensation shall be as set forth in Exhibit “B.” Compensation for necessary expenditures must be approved in advance by the Contract Officer designated under Section 4.2.

2.2. Method of Payment . Unless another method of payment is specified in the Schedule of Compensation, Exhibit “B”, City shall pay Contractor the annual sum for the Software, Maintenance, and Support Services, as defined in Exhibit “A”. Contractor shall submit to City an invoice referencing the Purchase Order and Agreement no sooner than forty -five (45) days prior to the commencement of each annual year of service. Such requests shall be based upon the amount and value of the services performed by Contractor and accompanied by such reporting data including an itemized breakdown of all costs incurred and tasks performed during the period covered by the invoice, as may be required by the City. City shall use reasonable efforts to make

payments to Contractor within forty -five (45) days after receipt of the invoice or as soon as is reasonably practical. There shall be a maximum of one payment per month.

2.3 Changes in Scope. In the event any change or changes in the Scope of Services is requested by City, Parties shall execute a written amendment to this Agreement, specifying all proposed amendments, including, but not limited to, any additional fees. An amendment may be entered into:

A. To provide for revisions or modifications to documents, work product, or work, when required by the enactment or revision of any subsequent law; or B. To provide for additional services not included in this Agreement or not customarily furnished in accordance with generally accepted practice in Contractor’s profession.

2.4 Appropriations. This Agreement is subject to and contingent upon funds being appropriated by the City Council for each fiscal year covered by the Agreement. If such appropriations are not made, this Agreement shall automatically terminate without penalty to the City.

3. SCHEDULE OF PERFORMANCE

3.1 Term. Unless earlier terminated in accordance with Section 4.5 of this Agreement, this Agreement shall continue in full force and effect for a period of 5 years, commencing on September 01, 2026, and ending on August 31, 2031, unless extended by mutual written agreement of the Parties. However, the term shall not exceed 5 years from the Effective Date, except as otherwise provided in the Schedule of Performance described in Section 3.3 below.

3.2 Termination Prior to Expiration of Term . The City may terminate this Agreement at any time, with or without cause, upon thirty (30) days written notice to Contractor.

Where termination is due to the fault of Contractor and constitutes an immediate danger to health, safety, and general welfare, the period of notice shall be such shorter time as may be determined by the City. Upon receipt of the notice of termination, Contractor shall immediately cease all Services except such as may be specifically approved by the Contract Officer. Contractor shall be entitled to compensation for all Services rendered prior to receipt of the notice of termination and for any Services authorized by the Contract Officer after such notice. City shall not be liable for any costs other than the charges or portions thereof which are specified herein. Contractor shall not be entitled to payment for unperformed Services, and shall not be entitled to damages or compensation for termination of Work. Contractor may not terminate this Agreement except for cause, upon thirty (30) days written notice to City.

3.3 Schedule of Performance. Contractor shall commence the Services under this Agreement upon receipt of a written notice to proceed and shall perform all Services within the time period(s) established in the Schedule of Performance. When requested by Contractor, extensions to the time period(s) specified in the Schedule of Performance may be approved in writing by the Contract Officer, but such extensions shall not exceed one hundred eighty (180) days cumulatively; however, the City shall not be obligated to grant such an extension.

3.4 Force Majeure. The time for performance of Services to be rendered under this Agreement may be extended because of any delays due to a Force Majeure Event, if Contractor notifies the Contract Officer within ten (10) days of the commencement of the Force Majeure Event. A Force Majeure Event shall mean an event that materially affects the Contractor’s

performance and is one or more of the following: (1) Acts of God or other natural disasters occurring at the project site; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the Work); and (4) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of the City in its capacity as a municipal authority. After Contractor notification, the Contract Officer shall investigate the fact s and the extent of any necessary delay and extend the time for performing the Services for the period of the enforced delay when and if, in the Contract Officer’s judgment, such delay is justified.

The Contract Officer’s determination shall be final and conclusive upon the Parties to this Agreement. The Contractor will not receive an adjustment to the contract price or any other compensation. Notwithstanding the foregoing, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement.

4. COORDINATION OF WORK

4.1 Representative of Contractor. The following principal of Contractor is designated as being the principal and representative of Contractor authorized to act in its behalf and make all decisions with respect to the Services to be performed under this Agreement:

Maxwell Corotis. It is expressly understood that the experience, knowledge, education, capability, expertise, and reputation of the foregoing principal is a substantial inducement for City to enter into this Agreement. Therefore, the foregoing principal shall be responsible during the term of this Agreement for directing all activities of Contractor and devoting sufficient time to personally supervise the Services performed hereunder. The foregoing principal may not be changed by Contractor without prior written approval of the Contract Officer.

4.2 Contract Officer. The Contract Officer shall be the City Manager or his/her designee ("Contract Officer"). Contractor shall be responsible for keeping the Contract Officer fully informed of the progress of the performance of the Services. Contractor shall refer any decisions that must be made by City to the Contract Officer. Unless otherwise specified, any approval of City shall mean the approval of the Contract Officer.

4.3 Prohibition Against Subcontracting or Assignments. The experience, knowledge, education, capability, and reputation of Contractor, its principals and employees, were a substantial inducement for City to enter into this Agreement. Contractor shall not contract with any other individual or entity to perform any Services required under this Agreement without the City's express written approval. In addition, neither this Agreement nor any interest may be assigned or transferred, voluntarily or by operation of law, without the prior written approval of City. Subcontracts, if any, shall contain a provisions making them subject to all provisions stipulated in this Agreement including without limitation the insurance and indemnification requirements. If Contractor is permitted to subcontract any part of this Agreement by City, Contractor shall be responsible to City for the acts and omissions of its subcontractor(s) in the same manner as it is for persons directly employed. Nothing contained in this Agreement shall create any contractual relationships between any subcontractor and City. All persons engaged in the Work will be considered employees of Contractor. City will deal directly with and will make all payments to Contractor. In addition, neither this Agreement nor any interest in this Agreement may be transferred, assigned, conveyed, hypothecated, or encumbered voluntarily or by operation of law, whether for the benefit of creditors or otherwise, without the prior written consent of City. In the event of any such unapproved transfer, including any bankruptcy proceeding, this

Agreement shall be void. No approved transfer shall release Contractor or any surety of Contractor from any liability under this Agreement without the express written consent of City.

4.4 Independent Contractor. The legal relationship between the Parties is that of an independent contractor, and nothing shall be deemed to make Contractor a City employee.

A. During the performance of this Agreement, Contractor and its officers, employees, and agents shall act in an independent capacity and shall not act or represent themselves as City officers or employees. The personnel performing the Services under this Agreement on behalf of Contractor shall at all times be under Contractor’s exclusive direction and control. Neither City nor any of its officers, employees, or agents shall have control over the conduct of Contractor or any of its officers, employees, or agents, except as set forth in this Agreement. Contractor, its officers, employees, or agents shall not maintain an office or any other type of fixed business location at City’s offices. City shall have no voice in the selection, discharge, supervision, or control of Contractor’s employees, servants, representatives, or agents, or in fixing their number, compensation, or hours of service. Contractor shall pay all wages, salaries, and other amounts due its employees in connection with this Agreement and shall be responsible for all reports and obligations respecting them, including but not limited to social security income tax withholding, unemployment compensation, workers’ compensation, and other similar matters. City shall not in any way or for any purpose be deemed to be a partner of Contractor in its business or otherwise a joint venturer or a member of any joint enterprise with Contractor.

B. Contractor shall not have any authority to bind City in any manner. This includes the power to incur any debt, obligation, or liability against City.

C. No City benefits shall be available to Contractor, its officers, employees, or agents in connection with any performance under this Agreement. Except for contract fees paid to Contractor as provided for in this Agreement, City shall not pay salaries, wages, or other compensation to Contractor for the performance of Services under this Agreement. City shall not be liable for compensation or indemnification to Contractor, its officers, employees, or agents, for injury or sickness arising out of performing Services. If for any reason any court or governmental agency determines that the City has financial obligations, other than under Section 2 and Subsection 1.8 in this Agreement, of any nature relating to salary, taxes, or benefits of Contractor’s officers, employees, servants, representatives, subcontractors, or agents, Contractor shall indemnify City for all such financial obligations.

4.5 California Labor Code Requirements.

A. Contractor is aware of the requirements of California Labor Code Sections 1720 et seq. and 1770 et seq., which require the payment of prevailing wage rates and the performance of other requirements on certain “public works” and “maintenance” projects (“Prevailing Wage Laws”). If the Services are being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and if the total compensation is $15,000 or more for maintenance or $25,000 or more for construction, alteration, demolition, installation, or repair, Contractor agrees to fully comply with such Prevailing Wage Laws. Contractor shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claims, liabilities, costs, penalties or interest arising out of any failure or alleged failure to comply with the Prevailing Wage Laws. It shall be mandatory upon the Contractor and all subcontractors to comply with all California Labor Code provisions, which include but are not limited to prevailing wages (Labor Code Sections 1771, 1774 and 1775),

employment of apprentices (Labor Code Section 1777.5), certified payroll records (Labor Code Sections 1771.4 and 1776), hours of labor (Labor Code Sections 1813 and 1815) and debarment of contractors and subcontractors (Labor Code Section 1777.1).

B. If the Services are being performed as part of an applicable “public works” or “maintenance” project and if the total compensation is $15,000 or more for maintenance or $25,000 or more for construction, alteration, demolition, installation, or repair, then pursuant to Labor Code Sections 1725.5 and 1771.1, the Contractor and all subcontractors performing such Services must be registered with the Department of Industrial Relations. Contractor shall maintain registration for the duration of the Project and require the same of any subcontractors, as applicable. This Agreement may also be subject to compliance monitoring and enforcement by the Department of Industrial Relations. It shall be Contractor’s sole responsibility to comply with all applicable registration and labor compliance requirements.

5. INSURANCE

5.1 Types of Insurance. Contractor shall procure and maintain, at its sole cost and expense, the insurance described herein. The insurance shall be for the duration of this Agreement and includes any extensions, unless otherwise specified in this Agreement. The insurance shall be procured in a form and content satisfactory to City. The insurance shall apply against claims which may arise from the Contractor's performance of Work under this Agreement, including Contractor's agents, representatives, or employees. In the event the City Manager determines that the Work or Services to be performed under this Agreement creates an increased or decreased risk of loss to the City, the Contractor agrees that the minimum limits of the insurance policies may be changed accordingly upon receipt of written notice from the City Manager or his designee. Contractor shall immediately substitute any insurer whose A.M. Best rating drops below the levels specified in this Agreement. Except as otherwise authorized below for contract liability (errors and omissions) insurance, all insurance provided under this Agreement shall be on an occurrence basis. The minimum amount of insurance required shall be as follows:

A. Errors and Omissions Insurance. Contractor shall obtain and maintain in full force and effect throughout the term of this Agreement, standard industry form contract liability (errors and omissions) insurance coverage in an amount of not less than one million dollars ($1,000,000.00) per occurrence and two-million dollars ($2,000,000.00) annual aggregate, in accordance with the provisions of this section.

R equired
x is not required;
(1) Contractor shall either: (a) certify in writing to the City that Contractor is unaware of any contract liability claims made against Contractor and is unaware of any facts which may lead to such a claim against Contractor; or (b) if Contractor does not provide the certification under (a), Contractor shall procure from the contract liability insurer an endorsement providing that the required limits of the policy shall apply separately to claims arising from errors and omissions in the rendition of services under this Agreement.

(2) If the policy of insurance is written on a “claims made” basis, the policy shall be continued in full force and effect at all times during the term of this Agreement, and for a period of three (3) years from the date of the completion of the Services provided hereunder. In the event of termination of the policy during this period, Contractor shall obtain continuing insurance coverage for the prior acts or omissions of Contractor during the course of performing

Services under the terms of this Agreement. The coverage shall be evidenced by either a new policy evidencing no gap in coverage, or by obtaining separate extended “tail” coverage with the present or new carrier or other insurance arrangements providing for complete coverage, either of which shall be subject to the written approval by the City Manager.

(3) In the event the policy of insurance is written on an “occurrence” basis, the policy shall be continued in full force and effect during the term of this Agreement, or until completion of the Services provided for in this Agreement, whichever is later. In the event of termination of the policy during this period, new coverage shall immediately be obtained to ensure coverage during the entire course of performing the Services under the terms of this Agreement.

B. Workers’ Compensation Insurance. Contractor shall obtain and maintain, in full force and effect throughout the term of this Agreement, workers’ compensation insurance in at least the minimum statutory amounts, and in compliance with all other statutory requirements, as required by the State of California. Contractor agrees to waive and obtain endorsements from its workers’ compensation insurer waiving subrogation rights under its workers’ compensation insurance policy against the City and to require each of its subcontractors, if any, to do likewise under their workers’ compensation insurance policies. If Contractor has no employees, Contractor shall complete the City’s Request for Waiver of Workers’ Compensation Insurance Requirement form.

C. Commercial General Liability Insurance. Contractor shall obtain and maintain, in full force and effect throughout the term of this Agreement, a policy of commercial general liability insurance written on a per occurrence basis with a combined single limit of at least one million dollars ($1,000,000.00) and two million dollars ($2,000,000.00) general aggregate for bodily injury and property damage including coverages for contractual liability, personal injury, independent contractors, broad form property damage, products and completed operations.

D. Business Automobile Insurance. Contractor shall obtain and maintain, in full force and effect throughout the term of this Agreement, a policy of business automobile liability insurance written on a per occurrence basis with a single limit liability in the amount of one million dollars ($1,000,000.00) bodily injury and property damage. The policy shall include coverage for owned, non-owned, leased, and hired cars.

E. Employer Liability Insurance. Contractor shall obtain and maintain, in full force and effect throughout the term of this Agreement, a policy of employer liability insurance written on a per occurrence basis with a policy limit of at least one million dollars ($1,000,000.00) for bodily injury or disease.

5.2 Deductibles and Self -Insured Retentions. Any deductibles or self-insured retentions must be declared to and approved by the City Manager or his/her designee prior to commencing any work or services under this Agreement. Contractor guarantees payment of all deductibles and self-insured retentions. City reserves the right to reject deductibles or self- insured retentions in excess of $10,000, and the City Manager or his/her designee may require evidence of pending claims and claims history as well as evidence of Contractor’s ability to pay claims for all deductible amounts and self-insured retentions proposed in excess of $10,000.

5.3 Other Insurance Requirements. The following provisions shall apply to the insurance policies required of Contractor under this Agreement:

A. For any claims related to this Agreement, Contractor’s coverage shall be

primary insurance with respect to the City and its officers, council members, officials, employees, agents, and volunteers. Any insurance or self-insurance maintained by the City and its officers, council members, officials, employees, agents, and volunteers shall be in excess of Contractor’s insurance and shall not contribute with it.

B. Any failure to comply with reporting or other provisions of the policies, including breaches of warranties, shall not affect coverage provided to City and its officers, council members, officials, employees, agents, and volunteers.

C. All insurance coverage and limits provided by Contractor and available or applicable to this Agreement are intended to apply to each insured, including additional insureds, against whom a claim is made or suit is brought to the full extent of the policies. Nothing contained in this Agreement or any other agreement relating to the City or its operations shall limit the application of such insurance coverage.

D. No required insurance coverages may include any limiting endorsement which substantially impairs the coverages set forth in this Agreement (e.g., elimination of contractual liability or reduction of discovery period), unless the endorsement has first been submitted to the City Manager and approved in writing.

E. Contractor agrees to require its insurer to modify insurance endorsements to delete any exculpatory wording stating that failure of the insurer to mail written notice of cancellation imposes no obligation, or that any party will "endeavor" (as opposed to being required) to comply with the requirements of the endorsements. Certificates of insurance will not be accepted in lieu of required endorsements, and submittal of certificates without required endorsements may delay commencement of the Project. It is Contractor’s obligation to ensure timely compliance with all insurance submittal requirements as provided in this Agreement.

F. Contractor agrees to ensure that subcontractors, and any other parties involved with the Project who are brought onto or involved in the Project by Contractor, provide the same minimum insurance coverage required of Contractor. Contractor agrees to monitor and review all such coverage and assumes all responsibility for ensuring that such coverage is provided in conformity with the requirements of this section. Contractor agrees that upon request, all agreements with subcontractors and others engaged in the Project will be submitted to the City for review.

G. Contractor acknowledges and agrees that any actual or alleged failure on the part of the City to inform Contractor of non-compliance with any insurance requirement in no way imposes any additional obligations on the City nor does it waive any rights in this or any other regard.

H. Contractor shall provide proof that policies of insurance required in this Agreement, expiring during the term of this Agreement, have been renewed or replaced with other policies providing at least the same coverage. Proof that such coverage has been ordered shall be submitted prior to expiration. Endorsements as required in this Agreement applicable to the renewing or new coverage shall be provided to City no later than ten (10) days prior to expiration of the lapsing coverage.

I. Requirements of specific insurance coverage features or limits contained in this section are not intended as limitations on coverage, limits, or other requirements, or as a waiver of any coverage normally provided by any given policy. Specific reference to a given

coverage feature is for purposes of clarification only as it pertains to a given issue, and is not intended by any party or insured to be limiting or all-inclusive.

J. The requirements in this section supersede all other sections and provisions of this Agreement to the extent that any other section or provision conflicts with or impair the provisions of this section.

K. Contractor agrees to provide immediate notice to City of any claim or loss against Contractor arising out of the Work performed under this Agreement and for any other claim or loss which may reduce the insurance available to pay claims arising out of this Agreement. City assumes no obligation or liability by such notice, but has the right (but not the duty) to monitor the handling of any such claim or claims if they are likely to involve City, or to reduce or dilute insurance available for payment of potential claims.

L. Contractor agrees that the provisions of this section shall not be construed as limiting in any way the extent to which the Contractor may be held responsible for the payment of damages resulting from the Contractor’s activities or the activities of any person or person for which the Contractor is otherwise responsible.

5.4 Sufficiency of Insurers. Insurance required in this Agreement shall be provided by authorized insurers in good standing with the State of California. Coverage shall be provided by insurers admitted in the State of California with an A.M. Best’s Key Rating of B++, Class VII, or better, unless such requirements are waived in writing by the City Manager or his designee due to unique circumstances.

5.5 Verification of Coverage. Contractor shall furnish City with both certificates of insurance and endorsements, including additional insured endorsements, affecting all of the coverages required by this Agreement. The certificates and endorsements are to be signed by a person authorized by that insurer to bind coverage on its behalf. All proof of insurance is to be received and approved by the City before work commences. City reserves the right to require Contractor’s insurers to provide complete, certified copies of all required insurance policies at any time. Additional insured endorsements are not required for Errors and Omissions and Workers’ Compensation policies.

Verification of Insurance coverage may be provided by: (1) an approved General and/or Auto Liability Endorsement Form for the City of Palm Springs or (2) an acceptable Certificate of Liability Insurance Coverage with an approved Additional Insured Endorsement with the following endorsements stated on the certificate:

A. "The City of Palm Springs, its officials, employees, and agents are named as an additional insured…” ("as respects City of Palm Springs Contract No.___" or "for any and all work performed with the City" may be included in this statement).

B. "This insurance is primary and non-contributory over any insurance or self- insurance the City may have..." (" as respects City of Palm Springs Contract No.___" or "for any and all work performed with the City" may be included in this statement).

C. "Should any of the above described policies be canceled before the expiration date thereof, the issuing company will mail 30 days written notice to the Certificate Holder named." Language such as, “endeavor to” mail and "but failure to mail such notice shall impose no

obligation or liability of any kind upon the company, its agents or representative" is not acceptable and must be crossed out.

D. Both the Workers’ Compensation and Employers' Liability policies shall contain the insurer's waiver of subrogation in favor of City, its elected officials, officers, employees, agents, and volunteers.

In addition to the endorsements listed above, the City of Palm Springs shall be named the certificate holder on the policies. All certificates of insurance and endorsements are to be received and approved by the City before work commences. All certificates of insurance must be authorized by a person with authority to bind coverage, whether that is the authorized agent/broker or insurance underwriter. Failure to obtain the required documents prior to the commencement of work shall not waive the Contractor’s obligation to provide them.

6. INDEMNIFICATION

6.1 Indemnification and Reimbursement. To the fullest extent permitted by law, Contractor shall defend (at Contractor’s sole cost and expense), indemnify, protect, and hold harmless City, its elected officials, officers, employees, agents, and volunteers (collectively the “Indemnified Parties”), from and against any and all liabilities, actions, suits, claims, demands, losses, costs, judgments, arbitration awards, settlements, damages, demands, orders, penalties, and expenses including legal costs and attorney fees (collectively “Claims”), including but not limited to Claims arising from injuries to or death of persons (Contractor’s employees included), for damage to property, including property owned by City, for any violation of any federal, state, or local law or ordinance or in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct committed by Contractor, its officers, employees, representatives, and agents, that arise out of or relate to Contractor’s performance of Services or this Agreement. This indemnification clause excludes Claims arising from the sole negligence or willful misconduct of the Indemnified Parties. Under no circumstances shall the insurance requirements and limits set forth in this Agreement be construed to limit Contractor’s indemnification obligation or other liability under this Agreement. Contractor’s indemnification obligation shall survive the expiration or earlier termination of this Agreement until all actions against the Indemnified Parties for such matters indemnified are fully and finally barred by the applicable statute of limitations or, if an action is timely filed, until such action is final.

6.2 Design Contract Services Indemnification and Reimbursement.

If Contractor’s obligation to defend, indemnify, and/or hold harmless arises out of Contractor’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Contractor’s indemnification obligation shall be limited to the extent which the Claims arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Contractor in the performance of the Services or this Agreement, and, upon Contractor obtaining a final adjudication by a court of competent jurisdiction, Contractor’s liability for such claim, including the cost to defend, shall not exceed the Contractor’s proportionate percentage of fault.

7. REPORTS AND RECORDS

7.1 Accounting Records. Contractor shall keep complete, accurate, and detailed accounts of all time, costs, expenses, and expenditures pertaining in any way to this Agreement.

Contractor shall keep such books and records as shall be necessary to properly perform the

Services required by this Agreement and to enable the Contract Officer to evaluate the performance of such Services. The Contract Officer shall have full and free access to such books and records at all reasonable times, including the right to inspect, copy, audit, and make records and transcripts from such records.

7.2 Reports. Contractor shall periodically prepare and submit to the Contract Officer such reports concerning the performance of the Services required by this Agreement, or as the Contract Officer shall require. Contractor acknowledges that the City is greatly concerned about the cost of the Work to be performed under this Agreement. For this reason, Contractor agrees that Contractor shall promptly notify the Contract Officer the estimated increased or decreased cost if Contractor becomes aware of any facts, circumstances, techniques, or events that may or will materially increase or decrease the cost of the Services. If Contractor is providing design services, Contractor shall promptly notify the Contract Officer the estimated increased or decreased cost for the proj ect being designed if Contractor becomes aware of any facts, circumstances, techniques, or events that may or will materially increase or decrease the cost of the design services.

7.3 Ownership of Documents. All drawings, specifications, reports, records, documents, memoranda, correspondence, computations, and other materials prepared by Contractor, its employees, subcontractors, and agents in the performance of this Agreement shall be the property of City and shall be promptly delivered to City upon request of the Contract Officer or upon the termination of this Agreement. Contractor shall have no claim for further employment or additional compensation as a result of the exercise by City of its full rights of ownership of the documents and materials. Any use of such completed documents for other projects and/or use of incomplete documents without specific written authorization by the Contractor will be at the City's sole risk and without liability to Contrac tor, and the City shall indemnify the Contractor for all resulting damages. Contractor may retain copies of such documents for their own use.

Contractor shall have an unrestricted right to use the concepts embodied tin this Agreement.

Contractor shall ensure that all its subcontractors shall provide for assignment to City of any documents or materials prepared by them. In the event Contractor fails to secure such assignment, Contractor shall indemnify City for all resulting damages.

7.4 Release of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Contractor in the performance of Services under this Agreement shall not be released publicly without the prior written approval of the Contract Officer.

All information gained by Contractor in the performance of this Agreement shall be considered confidential and shall not be released by Contractor without City’s prior written authorization.

7.5 Audit and Inspection of Records. After receipt of reasonable notice and during the regular business hours of City, Contractor shall provide City, or other agents of City, such access to Contractor’s books, records, payroll documents, and facilities as City deems necessary to examine, copy , audit, and inspect all accounting books, records, work data, documents, and activities directly related to Contractor’s performance under this Agreement. Contractor shall maintain such books, records, data, and documents in accordance with generally accepted accounting principles and shall clearly identify and make such items readily accessible to such parties during the term of this Agreement and for a period of three (3) years from the date of final payment by City hereunder.

8. ENFORCEMENT OF AGREEMENT

8.1 California Law and Venue. This Agreement shall be construed and interpreted

both as to validity and as to performance of the Parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim, or matter arising out of or in relation to this Agreement shall be instituted in the Superior Court of the County of Riverside, State of California, or any other appropriate court in such County, and Contractor covenants and agrees to submit to the personal jurisdiction of such court in the event of such action.

8.2 Interpretation. This Agreement shall be construed as a whole according to its fair language and common meaning to achieve the objectives and purposes of the Parties. The terms of this Agreement are contractual and the result of negotiation between the Parties. Accordingl y, any rule of construction of contracts (including, without limitation, California Civil Code Section 1654) that ambiguities are to be construed against the drafting party, shall not be employed in the interpretation of this Agreement. The caption headings of the various sections and paragraphs of this Agreement are for convenience and identification purposes only and shall not be deemed to limit, expand, or define the contents of the respective sections or paragraphs.

8.3 Default of Contractor. Contractor’s failure to comply with any provision of this Agreement shall constitute a default.

A. If the City Manager, or his designee, determines that Contractor is in default in the performance of any of the terms or conditions of this Agreement, he/she shall notify Contractor in writing of such default. Contractor shall have ten (10) days, or such longer period as City may designate, to cure the default by rendering satisfactory performance. In the event Contractor fails to cure its default within such period of time, City shall have the right, notwithstanding any other provision of this Agreement, to terminate this Agreement without further notice and without prejudice of any remedy to which City may be entitled at law, in equity, or under this Agreement. Contractor shall be liable for all reasonable costs incurred by City as a result of such default. Compliance with the provisions of this section shall not constitute a waiver of any City right to take legal action in the event that the dispute is not cured, provided that nothing shall limit City’s right to terminate this Agreement without cause under Section 3.2.

B. If termination is due to the failure of the Contractor to fulfill its obligations under this Agreement, City may, after compliance with the provisions of Section 8.3(A), take over the work and prosecute the same to completion by contract or otherwise. The Contractor shall be liable to the extent that the total cost for completion of the Services required hereunder exceeds the Maximum Contract Amount (provided that the City shall use reasonable efforts to mitigate such damages). The City may withhold any payments to the Contractor for the purpose of set-off or partial payment of the amounts owed the City as previously stated. The withholding or failure to withhold payments to Contractor shall not limit Contractor’s liability for completion of the Services as provided in this Agreement.

8.4 Waiver. No waiver of any provision of this Agreement shall be effective unless in writing and signed by a duly authorized representative of the Party against whom enforcement of a waiver is sought. Any waiver by the Parties of any default or breach of any covenant, condition, or term contained in this Agreement, shall not be construed to be a waiver of any subsequent or other default or breach, nor shall failure by the Parties to require exact, full, and complete compliance with any of the covenants, conditions, or terms contained in this Agreement be construed as changing the terms of this Agreement in any manner or preventing the Parties from enforcing the full provisions.

8.5 Rights and Remedies Cumulative. Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the Parties are

cumulative and the exercise by either Party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other Party.

8.6 Legal Action. In addition to any other rights or remedies, either Party may take legal action, in law or in equity, to cure, correct, remedy or recover damages for any default, to compel specific performance of this Agreement, to obtain declaratory or injunctive relief, or to obtain any other remedy consistent with the purposes of this Agreement.

8.7 Attorney Fees. In the event any dispute between the Parties with respect to this Agreement results in litigation or any non-judicial proceeding, the prevailing Party shall be entitled, in addition to such other relief as may be granted, to recover from the non-prevailing Party all reasonable costs and expenses. These include but are not limited to reasonable attorney fees, expert contractor fees, court costs and all fees, costs, and expenses incurred in any appeal or in collection of any judgment entered in such proceeding.

9. CITY OFFICERS AND EMPLOYEES: NON-DISCRIMINATION

9.1 Non-liability of City Officers and Employees. No officer or employee of the City shall be personally liable to the Contractor, or any successor-in-interest, in the event of any default or breach by the City or for any amount which may become due to the Contractor or to its successor, or for breach of any obligation of the terms of this Agreement.

9.2 Conflict of Interest. Contractor acknowledges that no officer or employee of the City has or shall have any direct or indirect financial interest in this Agreement nor shall Contractor enter into any agreement of any kind with any such officer or employee during the term of thi s Agreement and for one (1) year thereafter. Contractor warrants that Contractor has not paid or given, and will not pay or give, any third party any money or other consideration in exchange for obtaining this Agreement.

9.3 Covenant Against Discrimination. In connection with its performance under this Agreement, Contractor shall not discriminate against any employee or applicant for employment because of actual or perceived race, religion, color, sex, age, marital status, ancestry, national origin ( i.e., place of origin, immigration status, cultural or linguistic characteristics, or ethnicity), sexual orientation, gender identity, gender expression, physical or mental disability, or medical condition (each a “prohibited basis”). Contractor shall ensure that applicants are employed, and that employees are treated during their employment, without regard to any prohibited basis. As a condition precedent to City’s lawful capacity to enter this Agreement, and in executing this Agreement, Contractor certifies that its actions and omissions hereunder shall not incorporate any discrimination arising from or related to any prohibited basis in any Contractor activity, including but not limited to the following: employment, upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship; and further, that Contractor is in full compliance with the provisions of Palm Springs Municipal Code Section 7.05 .02, including without limitation the provision of benefits, relating to non-discrimination in city contracting.

10. MISCELLANEOUS PROVISIONS

10.1 Patent and Copyright Infringement. To the fullest extent permissible under law, and in lieu of any other warranty by City or Contractor against patent or copyright infringement, statutory or otherwise:

A. It is agreed that Contractor shall defend at its expense any claim or suit against City on account of any allegation that any item furnished under this Agreement, or the normal use or sale arising out of the performance of this Agreement, infringes upon any presently existing U.S. letters patent or copyright and Contractor shall pay all costs and damages finally awarded in any such suit or claim, provided that Contractor is promptly notified in writing of the suit or claim and given authority, information and assistance at Contractor’s expense for the defense of same, and provided such suit or claim arises out of, pertains to, or is related to the negligence, recklessness or willful misconduct of Contractor. However, Contractor will not indemnify City if the suit or claim results from: (1) City's alteration of a deliverable, such that City’s alteration of such deliverable created the infringement upon any presently existing U.S. letters patent or copyright; or (2) the use of a deliverable in combination with other material not provided by Contractor when it is such use in combination which infringes upon an existing U.S. letters patent or copyright.

B. Contractor shall have sole control of the defense of any such claim or suit and all negotiations for settlement in the event City fails to cooperate in the defense of any suit or claim, provided, however, that such defense shall be at Contractor’s expense. Contractor shall not be obligated to indemnify City under any settlement that is made without Contractor’s consent, which shall not be unreasonably withheld. If the use or sale of such item is enjoined as a result of the suit or claim, Contractor, at no expense to City, shall obtain for City the right to use and sell the item, or shall substitute an equivalent item acceptable to City and extend this patent and copyright indemnity thereto.

10.2 Notice. Any notice, demand, request, consent, approval, or communication that either party desires, or is required to give to the other party or any other person shall be in writing.

All notices shall be personally delivered, sent by pre-paid First Class U.S. Mail, registered or certified mail, postage prepaid, return receipt requested, or delivered or sent by facsimile with attached evidence of completed transmission. All notices shall be deemed received upon the earlier of (i) the date of delivery to the address of the person to receive such notice if delivered personally or by messenger or overnight courier; (ii) five (5) business days after the date of posting by the United States Post Office if by mail; or (iii) when sent if given by facsimile. Any notice, request, demand, direction, or other communication sent by facsimile must be confirmed within forty-eight (48) hours by letter mailed or delivered. Other forms of electronic transmission such as e-mails, text messages, and instant messages are not acceptable manners of notice required hereunder. Notices or other communications shall be addressed as follows:

To City: City of Palm Springs
Attention: City Manager & City Clerk
3200 E. Tahquitz Canyon Way
Palm springs, California 92262
Telephone: (760) 323-8204
Facsimile: (760) 323-8332

To Contractor: Skidata, Inc
Attention: Maxwell Corotis
6611 Odessa Avenue,
Van Nuys, CA 91406
Tel (619) 695-4183

10.3 Integrated Agreement . This Agreement constitutes the entire understanding between the Parties and supersedes and cancels all prior negotiations, arrangements, agreements, representations, and understandings, if any, made by or among the Parties with respect to the subject matter in this Agreement.

10.4 Amendment. No amendments or other modifications of this Agreement shall be binding unless through written agreement signed by all Parties.

10.5 Severability. Whenever possible, each provision of this Agreement shall be interpreted in such a manner as to be effective and valid under applicable law. If any provision of this Agreement shall be determined to be invalid by a final judgment or decree of a court of competent jurisdiction, such provision shall be ineffective only to the extent of such prohibition or invalidity, without invalidating the reminder of that provision, or the remaining provisions of this Agreement unless the invalid provision is so material that its invalidity deprives either Party of the basic benefit of their bargain or renders this Agreement meaningless.

10.6 Successors in Interest . This Agreement shall be binding upon and inure to the benefit of the Parties’ successors and assignees.

10.7 Third Party Beneficiary. Except as may be expressly provided for in this Agreement, nothing contained in this Agreement is intended to confer, nor shall this Agreement be construed as conferring, any rights, including, without limitation, any rights as a third-party beneficiary or otherwise, upon any entity or person not a party to this Agreement.

10.8 Recitals. The above-referenced Recitals are hereby incorporated into the Agreement as though fully set forth in this Agreement and each Party acknowledges and agrees that such Party is bound, for purposes of this Agreement, by the same.

10.9 Corporate Authority. Each of the undersigned represents and warrants that (i) the Party for which he or she is executing this Agreement is duly authorized and existing, (ii) he or she is duly authorized to execute and deliver this Agreement on behalf of the Party for which he or she is signing, (iii) by so executing this Agreement, the Party for which he or she is signing is formally bound to the provisions of this Agreement, and (iv) the entering into this Agreement does not violate any provision of any other Agreement to which the Party for which he or she is signing is bound.

10.10 Counterparts. This Agreement may be signed in counterparts, each of which shall constitute an original.

10.11 Compliance with Economic Sanctions in Response to Russia's Actions in Ukraine. When funding for the services is provided, in whole or in part, by an agency controlled of the State of California, Consultant shall fully and adequately comply with California Executive Order N-6-22 (“Russian Sanctions Program”). As part of this compliance process, Consultant shall also certify compliance with the Russian Sanctions Program by completing the form located in Exhibit “C” (Russian Sanctions Certification), attached hereto and incorporated herein by reference. Consultant shall also require any subconsultants to comply with the Russian Sanctions Program and certify compliance pursuant to this Section.

10.11 Federal Provisions. Since funding for the Services is provided, in whole or in part, by the Federal Aviation Administration, Contractor shall also fully and adequately comply with the

provisions included in Exhibit “D” attached hereto and incorporated herein by reference (“Federal Provisions”). With respect to any conflict between such Federal Provisions and the terms of this Agreement and/or the provisions of state law, the more stringent requirement shall control.

[SIGNATURES ON NEXT PAGE]

SIGNATURE PAGE TO CONTRACT SERVICES AGREEMENT BY AND BETWEEN THE CITY OF PALM SPRINGS AND SKIDATA, INC.

IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below.

CONTRACTOR:

By: _____________________________ By: _____________________________ Signature Signature
(2nd signature required for Corporation)

Date: ___________________________ Date: ___________________________

CITY OF PALM SPRINGS:

APPROVED BY CITY COUNCIL:

Date: _________________ Item No. ________ Agreement No. _________

APPROVED AS TO FORM: ATTEST:

By: _____________________________ By: _____________________________ City Attorney City Clerk

APPROVED:

By: _____________________________ Date: ____________________________ City Manager – up to $150,000
Deputy/Assistant City Manager – up to $50,000
Director – up to $25,000
Manager – up to $5,000

EXHIBIT “A”

SCOPE OF SERVICES

EXHIBIT “B”

SCHEDULE OF COMPENSATION

EXHIBIT “C”

EXHIBIT “D”

FEDERAL AVIATION ADMINISTRATION – FEDERAL PROVISIONS

Provision
Reference Provision Description
Page
No.

FAA - 01 Access to Records and Reports 2
FAA – 02 Breach of Contract Terms 3
FAA – 03 Buy American Preference * 4
FAA – 04 Civil Rights General 5
FAA – 05 Civil Rights – Title VI Assurances * 6
FAA – 06 Clean Air and Water Pollution Control 9
FAA – 07 Contract Work Hours and Safety Standards Act
Requirements
10 FAA – 08 Copeland Anti-Kickback Act 12
FAA – 09 Davis Bacon Requirements 13
FAA – 10 Debarment and Suspension * 20
FAA – 11 Disadvantaged Business Enterprise * 21
FAA – 12 Distracted Driving 22
FAA – 13 Prohibition on Certain Telecommunications and Video Surveillance Services or Equipment
23 FAA – 14 Drug Free Workplace Requirements (not applicable to Contractors)
24 FAA – 15 Federal Fair Labor Standards Act * 25
FAA – 16 Lobbying and Influencing Federal Employees 26
FAA – 17 Occupational Safety and Health Act of 1970 27
FAA – 18 Procurement of Recovered Materials * 28
FAA – 19 Right to Inventions 29
FAA – 20 Seismic Safety 30
FAA – 21 Tax Delinquency and Felony Convictions* 31
FAA – 22 Termination of Contract 32
FAA – 23 Trade Restriction Certification (Foreign) * 33 FAA – 24 Veteran’s Preference 35
FAA – 25 Domestic Preferences for Procurements * 36
FAA – 26 Prohibition of Covered Unmanned Aircraft Systems (UAS)
37 *Solicitation Clause also
Updated 01.12.2026

FAA - 01 Access to Records and Reports
APPLICABILITY – pertains to all contracts.

The Contractor must maintain an acceptable cost accounting system. The Contractor agrees to provide the City, the Federal Aviation Administration and the Comptroller General of the United States or any of their duly authorized representatives access to any books, documents, papers and records of the Contractor which are directly pertinent to the specific contract for the purpose of making audit, examination, excerpts and transcriptions. The Contractor agrees to maintain all books, records and reports required under this contract for a period of not less than three years after final payment is made and all pending matters are closed.

Reference: 2 CFR § 200.334, 2 CFR § 200.337, FAA Order 5100.38

FAA – 02 Breach of Contract
APPLICABILITY – required for all contracts that exceed the simplified acquisition threshold as stated in 2 CFR Part 200, Appendix II (A). This threshold is occasionally adjusted for inflation and is $350,000.

REQUIREMENT -
See Section 8.3 of the Agreement.

Reference: 2 CFR § 200 Appendix II(A)

FAA – 03 Buy American Preferences
APPLICABILITY – required for contracts defined as follows:
• Construction Projects involving the replacement, rehabilitation, reconstruction of airfield surfaces such as on runways, taxiways, taxilanes, aprons, roadways, parking lots, etc. – Insert the Certificate of compliance to FAA Buy American Preference based on Construction Projects.
• Equipment and Buildings Projects involving and including the acquisition of equipment such as snow removal equipment, navigational aids, wind cones, and the construction of buildings such as hangars, terminal development, lighting vaults, aircraft rescue & firefighting buildings, etc. - Insert the Certificate of Compliance with FAA Buy American Preference Based on Equipment/Building Projects.

REQUIREMENT –
The Contractor certifies that its bid/offer is in compliance with 49 U.S.C. § 50101, BABA and other related Made in America Laws,2 U.S. statutes, guidance, and FAA policies, which provide that Federal funds may not be obligated unless all iron, steel and manufactured goods used in AIP funded projects are produced in the United States, unless the Federal Aviation Administration has issued a waiver for the product; the product is listed as an Excepted Article, Material Or Supply in Federal Acquisition Regulation subpart 25.108; or is included in the FAA Nationwide Buy American Waivers Issued list.

The bidder or offeror must complete and submit the certification of compliance with FAA’s Buy American Preference, BABA and Made in America laws included herein with their bid or offer. The Airport Sponsor/Owner will reject as nonresponsive any bid or offer that does not include a completed certification of compliance with FAA’s Buy American Preference and BABA.

The bidder or offeror certifies that all constructions materials, defined to mean an article, material, or supply other than an item of primarily iron or steel; a manufactured product; cement and cementitious materials; aggregates such as stone, sand, or gravel; or aggregate binding agents or additives that are or consist primarily of: non-ferrous metals; plastic and polymer-based products (including polyvinylchloride, composite building materials, and polymers used in fiber optic cables); glass (including optic glass); lumber; or drywall used in the project are manufactured in the U.S.

The bidder/offeror must complete the certification statement found in Section _7 __ of the IFB/RFP/RFQ to be considered responsive.

Reference: Title 49 USC § 50101, Executive Order 14005

FAA – 04 Civil Rights General
APPLICABILITY – required for all contracts regardless of funding source.

REQUIREMENT -
In all its activities within the scope of its airport program, the Contractor agrees to comply with pertinent statutes, Executive Orders, and such rules as identified in Title VI List of Pertinent Nondiscrimination Acts and Authorities to ensure that no person shall, on the grounds of race, color, national origin, creed, sex, age, or disability be excluded from participating in any activity conducted with or benefiting from Federal assistance.

This provision is in addition to that required by Title VI of the Civil Rights Act of 1964.

In addition to the above, the following clauses apply to specific contract types:

APPLICABILITY – required for all General Contract Agreements:

REQUIREMENT -
The above provision binds the Contractor and subcontractors from the bid solicitation period through the completion of the contract.

APPLICABILITY – Lease Agreements
If the Contractor transfers its obligation to another, the transferee is obligated in the same manner as the Contractor.

The above provision obligates the Contractor for the period during which the property is owned, used or possessed by the Contractor and the airport remains obligated to the Federal Aviation Administration.

Reference: 49 USC § 47123

FAA – 05 Civil Rights – Title VI Assurances
APPLICABILITY – required for all contracts.

REQUIREMENT -
Title VI List of Pertinent Nondiscrimination Acts and Authorities During the performance of this contract, the Contractor, for itself, its assignees, and successors in interest (hereinafter referred to as the “Contractor”) agrees to comply with the following non-discrimination statutes and authorities; including but not limited to:
• Title VI of the Civil Rights Act of 1964 (42 U.S.C. § 2000d et seq., 78 stat. 252) (prohibits discrimination on the basis of race, color, national origin); • 49 CFR Part 21 (Non-discrimination in Federally-Assisted programs of the Department of Transportation—Effectuation of Title VI of the Civil Rights Act of 1964) including amendments thereto;
• The Uniform Relocation Assistance and Real Property Acquisition Policies Act of 1970, (42 U.S.C.§ 4601) (prohibits unfair treatment of persons displaced or whose property has been acquired because of Federal or Federal-aid programs and projects); • Section 504 of the Rehabilitation Act of 1973 (29 U.S.C. § 794 et seq.), as amended (prohibits discrimination on the basis of disability); and 49 CFR part 27 (Nondiscrimination on the Basis of Disability in Programs or Activities Receiving Federal Financial Assistance); • The Age Discrimination Act of 1975, as amended (42 .U.S.C. § 6101 et seq.) (prohibits discrimination on the basis of age);
• Airport and Airway Improvement Act of 1982 (49 U.S.C. § 47123), as amended (prohibits discrimination based on race, creed, color, national origin, or sex); • The Civil Rights Restoration Act of 1987 (P.L. 100-259) (broadened the scope, coverage and applicability of Title VI of the Civil Rights Act of 1964, the Age Discrimination Act of 1975 and Section 504 of the Rehabilitation Act of 1973, by expanding the definition of the terms “programs or activities” to include all of the programs or activities of the Federal -aid recipients, sub-recipients and contractors, whether such programs or activities are Federally funded or not);
• Titles II and III of the Americans with Disabilities Act of 1990 (42 U.S.C. § 12101, et seq) (prohibits discrimination on the basis of disability in the operation of public entities, public and private transportation systems, places of public accommodation, and certain testing entities) as implemented by U.S. Department of Transportation regulations at 49 CFR Parts 37 and 38;
• Title IX of the Education Amendments of 1972, as amended, which prohibits you from discriminating because of sex in education programs or activities (20 U.S.C. § 1681, et seq).

Compliance with Nondiscrimination Requirements:

During the performance of this contract, the Contractor, for itself, its assignees, and successors in interest (hereinafter referred to as the “Contractor”), agrees as follows:

1. Compliance with Regulations: The Contractor (hereinafter includes consultants) will comply with the Title VI List of Pertinent Nondiscrimination Acts and Authorities, as they may be amended from time to time, which are herein incorporated by reference and made a part of this contract.

2. Nondiscrimination: The Contractor, with regard to the work performed by it during the contract, will not discriminate on the grounds of race, color, national origin (including limited English proficiency), creed, sex (including sexual orientation and gender identity), age, or disability in the selection and retention of subcontractors, including procurements of materials and leases of equipment. The Contractor will not participate directly or indirectly in the discrimination prohibited by the Nondiscrimination Acts and Authorities, including employment practices when the contract covers any activity, project, or program set forth in Appendix B of 49 CFR part 21 including amendments thereto.

3. Solicitations for Subcontracts, including Procurements of Materials and Equipment:

In all solicitations, either by competitive bidding or negotiation made by the Contractor for work to be performed under a subcontract, including procurements of materials, or leases of equipment, each potential subcontractor or supplier will be notified by the Contractor of the Contractor’s obligations under this contract and the Nondiscrimination Acts and Authorities on the grounds of race, color, or national origin.

4. Information and Reports: The Contractor will provide all information and reports required by the Acts, the Regulations, and directives issued pursuant thereto and will permit access to its books, records, accounts, other sources of information, and its facilities as may be determined by the City or the Federal Aviation Administration to be pertinent to ascertain compliance with such Nondiscrimination Acts and Authorities and instructions. Where any information required of a Contractor is in the exclusive possession of another who fails or refuses to furnish the information, the Contractor will so certify to the City or the Federal Aviation Administration, as appropriate, and will set forth what efforts it has made to obtain the information.

5. Sanctions for Noncompliance: In the event of a Contractor’s noncompliance with the non- discrimination provisions of this contract, the City will impose such contract sanctions as it or the Federal Aviation Administration may determine to be appropriate, including, but not limited to:
a. Withholding payments to the Contractor under the contract until the Contractor complies; and/or
b. Cancelling, terminating, or suspending a contract, in whole or in part.

6. Incorporation of Provisions: The Contractor will include the provisions of paragraphs one through six in every subcontract, including procurements of materials and leases of equipment, unless exempt by the Acts, the Regulations, and directives issued pursuant thereto. The Contractor will take action with respect to any subcontract or procurement as the City or the Federal Aviation Administration may direct as a means of enforcing such

provisions including sanctions for noncompliance. Provided, that if the Contractor becomes involved in, or is threatened with litigation by a subcontractor, or supplier because of such direction, the Contractor may request the City to enter into any litigation to protect the interests of the City. In addition, the Contractor may request the United States to enter into the litigation to protect the interests of the United States.

Reference: 49 USC § 47123, FAA Order 1400.11

FAA – 06 Clean Air/Water Pollution Control
APPLICABILITY – This provision is required for all contracts and lower tier contracts that exceed $150,000.

REQUIREMENT -
If the Agreement exceeds $150,000, Contractor agrees to comply with all applicable standards, orders, and regulations issued pursuant to the Clean Air Act (42 USC § 7401- 7671q) and the Federal Water Pollution Control Act as amended (33 USC § 1251- 1387).

The Contractor agrees to report any violation to the City immediately upon discovery. The City assumes responsibility for notifying the Environmental Protection Agency (EPA) and the Federal Aviation Administration.

Contractor must include this requirement in all subcontracts that exceeds $150,000.

Reference: 2 CFR § 200, Appendix II(G); 42 USC § 7401; 33 USC § 1251

FAA – 07 Contract Work Hours and Safety Standards
APPLICABILITY – This provision is required for contracts as follows:

Contract Work Hours and Safety Standards Act Requirements (CWHSSA) (40 USC §§ 3702 & 3704) requires contractors and subcontractors on covered contracts to pay laborers and mechanics employed in the performance of the contracts not less than one and one-half times their basic rate of pay for all hours worked over 40 in a workweek. CWHSSA prohibits unsanitary, hazardous, or dangerous working conditions on federally-assisted projects. The Wage and Hour Division (WHD) within the U.S. Department of Labor (DOL) enforces the compensation requirements of this Act, while DOL’s Occupational Safety and Health Administration (OSHA) enforces the safety and health requirements.

Contract Types –
Construction – This provision applies to all contracts and lower tier contracts that exceed $100,000, and employ laborers, mechanics, watchmen, and guards.

Equipment – This provision applies to any equipment project exceeding $100,000 that involves installation of equipment onsite (e.g., electrical vault equipment). This provision does not apply to equipment acquisition projects where the manufacture of the equipment takes place offsite at the vendor plant (e.g., ARFF and SRE vehicles).

Professional Services – This provision applies to professional service agreements that exceed $100,000 and employs laborers, mechanics, watchmen, and guards. This includes members of survey crews and exploratory drilling operations.

Property – While most land transactions do not involve employment of laborers, mechanics, watchmen, and guards, under certain circumstances, a property acquisition project could require such employment. Examples include the installation of property fencing or testing for environmental contamination

CONTRACT WORKHOURS AND SAFETY STANDARDS ACT REQUIREMENTS

1. Overtime Requirements.

No contractor or subcontractor contracting for any part of the contract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic, including watchmen and guards, in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek.

2. Violation; Liability for Unpaid Wages; Liquidated Damages.

In the event of any violation of the clause set forth in paragraph (1) of this clause, the Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1) of this clause, in the sum of $29 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1) of this clause.

3. Withholding for Unpaid Wages and Liquidated Damages.

The Federal Aviation Administration (FAA) or the City shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the Contractor or subcontractor under any such contract or any other Federal contract with the same prime Contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime Contractor, such sums as may be determined to be necessary to satisfy any liabilities of such Contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2) of this clause.

4. Subcontractors.

The Contractor or subcontractor shall insert in any subcontracts the clauses set forth in paragraphs (1) through (4) and also a clause requiring the subcontractor to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (1) through (4) of this clause.

Reference: 2 CFR Part 200, Appendix II(E); 29 CFR § 5.5(b); 40 USC § 3702; 40 USC § 3704

FAA – 08 Copeland Anti-Kickback

APPLICABILITY -
The Copeland (Anti-Kickback) Act (18 USC § 874 and 40 USC § 3145) makes it unlawful to induce by force, intimidation, threat of dismissal from employment, or by any other manner, any person employed in the construction or repair of public buildings or publ ic works, financed in whole or in part by the United States, to give up any part of the compensation to which that person is entitled under a contract of employment. The Copeland Act also requires each contractor and subcontractor to furnish weekly a statement of compliance with respect to the wages paid each employee during the preceding week.

Contract Types –
Construction – This provision applies to all construction contracts and subcontracts financed under the AIP that exceed $2,000.

Equipment – This provision applies to all equipment installation projects (e.g., electrical vault improvements) financed under the AIP that exceed $2,000. This provision does not apply to equipment acquisitions where the equipment is manufactured at the vendor’s plant (e.g., SRE and ARFF vehicles).

Professional Services –The emergence of different project delivery methods has created situations where Professional Service Agreements (PSAs) include tasks that meet the definition of construction, alteration, or repair as defined in 29 CFR Part 5. If such tasks result in work that qualifies as construction, alteration, or repair and it exceeds $2,000, the PSA must incorporate the Copeland Anti-kickback provision.

Property –Ordinarily, land acquisition projects would not involve employment of laborers or mechanics and thus the Copeland Anti-Kickback provision would not apply. However, land projects that involve installation of boundary fencing and demolition of structures would involve laborers and mechanics. The City must include this provision if the land acquisition project involves employment of laborers or mechanics for a contract exceeding $2,000.

REQUIREMENT -
Contractor must comply with the requirements of the Copeland “Anti-Kickback” Act (18 USC 874 and 40 USC 3145), as supplemented by Department of Labor regulation 29 CFR part

3. Contractor and subcontractors are prohibited from inducing, by any means, any person employed on the project to give up any part of the compensation to which the employee is entitled. The Contractor and each Subcontractor must submit to the City, a weekly statement on the wages paid to each employee performing on covered work during the prior week. City must report any violations of the Act to the Federal Aviation Administration.

Reference: 2 CFR Part 200, Appendix II(D); 29 CFR Parts 3 and 5

FAA – 09 Davis Bacon Requirements

APPLICABILITY -
The Davis-Bacon Act (40 USC §§ 3141-3144, 3146, and 3147) ensures that laborers and mechanics employed under the contract receive pay no less than the locally prevailing wages and fringe benefits as determined by the Department of Labor.

Contract Types –
Construction –all construction contracts and subcontracts that exceed $2,000 and include funding from the AIP.

Equipment – This provision applies to all equipment installation projects (e.g., electrical vault improvements) financed under the AIP that exceed $ 2,000. This provision does not apply to equipment acquisitions where the equipment is manufactured at the vendor’s plant (e.g., SRE and ARFF vehicles)
Professional Services – The emergence of different project delivery methods has created situations where Professional Service Agreements (PSAs) includes tasks that meet the definition of construction, alteration, or repair as defined in 29 CFR Part 5. If such tasks result in work that qualifies as construction, alteration, or repair and it exceeds $2,000, the PSA must incorporate this clause.

Property – Ordinarily, land acquisition projects would not involve employment of laborers or mechanics and thus the provision would not apply. However, land projects that involve installation of boundary fencing and demolition of structures would involve laborers and mechanics. The City must include this provision if the land acquisition project involves employment of laborers or mechanics for a contract exceeding $2,000.

Fencing Projects – Fencing projects that exceed $2,000 must include this provision.

DAVIS-BACON REQUIREMENTS

1. Minimum Wages.
(i) All laborers and mechanics employed or working upon the site of the work will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by the Secretary of Labor under the Copeland Act (29 CFR Part 3)), the full amount of wages and bona fide fringe benefits (or cash equivalent thereof) due at time of payment computed at rates not less than those contained in the wage determination of the Secretary of Labor which is attached hereto and made a part hereof, regardless of any contractual relationship which may be alleged to exist between the Contractor and such laborers and mechanics.

Contributions made or costs reasonably anticipated for bona fide fringe benefits under section 1(b)(2) of the Davis -Bacon Act on behalf of laborers or mechanics are considered wages paid to such laborers or mechanics, subject to the provisions of paragraph (1)(iv) of this section; also, regular contributions made or costs incurred for more than a weekly period (but not less often than quarterly) under plans, funds, or programs which cover the particular weekly period, are deemed to be constructively made or incurred during such weekly period.

Such laborers and mechanics shall be paid the appropriate wage rate and fringe benefits

on the wage determination for the classification of work actually performed, without regard to skill, except as provided in 29 CFR § 5.5(a)(4). Laborers or mechanics performing work in more than one classification may be compensated at the rate specified for each classification for the time actually worked therein: Provided, that the employer’s payroll records accurately set forth the time spent in each classification in which work is performed.

The wage determination (including any additional classification and wage rates conformed under (1)(ii) of this section) and the Davis -Bacon poster (WH-1321) shall be posted at all times by the Contractor and its subcontractors at the site of the work in a prominent and accessible place where it can easily be seen by the workers. (ii)(A) The contracting officer shall require that any class of laborers or mechanics, including helpers, which is not listed in the wage determination and which is to be employed under the contract shall be classified in conformance with the wage determination. The contracting officer shall approve an additional classification and wage rate and fringe benefits therefore only when the following criteria have been met:
(1) The work to be performed by the classification requested is not performed by a classification in the wage determination;
(2) The classification is utilized in the area by the construction industry; and (3) The proposed wage rate, including any bona fide fringe benefits, bears a reasonable relationship to the wage rates contained in the wage determination. (B) If the Contractor and the laborers and mechanics to be employed in the classification (if known), or their representatives, and the contracting officer agree on the classification and wage rate (including the amount designated for fringe benefits where appropriate), a report of the action taken shall be sent by the contracting officer to the Administrator of the Wage and Hour Division, U.S. Department of Labor, Washington, DC 20210. The Administrator, or an authorized representative, will approve, modify, or disapprove every additional classification action within 30 days of receipt and so advise the contracting officer or will notify the contracting officer within the 30-day period that additional time is necessary. (C) In the event the Contractor, the laborers, or mechanics to be employed in the classification, or their representatives, and the contracting officer do not agree on the proposed classification and wage rate (including the amount designated for fringe benefits, where appropriate), the contracting officer shall refer the questions, including the views of all interested parties and the recommendation of the contracting officer, to the Administrator for determination. The Administrator, or an authorized representative, will issue a determination within 30 days of receipt and so advise the contracting officer or will notify the contracting officer within the 30-day period that additional time is necessary. (D) The wage rate (including fringe benefits where appropriate) determined pursuant to subparagraphs (1)(ii) (B) or (C) of this paragraph, shall be paid to all workers performing work in the classification under this contract from the first day on which work is performed in the classification.
(iii) Whenever the minimum wage rate prescribed in the contract for a class of laborers or mechanics includes a fringe benefit which is not expressed as an hourly rate, the contractor

shall either pay the benefit as stated in the wage determination or shall pay another bona fide fringe benefit or an hourly cash equivalent thereof. (iv) If the Contractor does not make payments to a trustee or other third person, the Contractor may consider as part of the wages of any laborer or mechanic the amount of any costs reasonably anticipated in providing bona fide fringe benefits under a plan or program, Provided, that the Secretary of Labor has found, upon the written request of the Contractor, that the applicable standards of the Davis-Bacon Act have been met. The Secretary of Labor may require the Contractor to set aside in a separate account assets for the meeting of obligations under the plan or program.

2. Withholding. The Federal Aviation Administration or the C ity shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld from the Contractor under this contract or any other Federal contract with the same prime contractor, or any other federally -assisted contract subject to Davis - Bacon prevailing wage requirements, which is held by the same prime contractor, so much of the accrued payments or advances as may be considered necessary to pay laborers and mechanics, including apprentices, trainees, and helpers, employed by the Contractor or any subcontractor the full amount of wages required by the contract. In the event of failure to pay any laborer or mechanic, including any apprentice, trainee, or helper, employed or working on the site of the work, all or part of the wages required by the contract, the Federal Aviation Administration may, after written notice to the Contractor, City, Applicant, or Owner, take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds until such violations have ceased.

3. Payrolls and Basic Records.
(i) Payrolls and basic records relating thereto shall be maintained by the Contractor during the course of the work and preserved for a period of three years thereafter for all laborers and mechanics working at the site of the work. Such records shall contain the name, address, and social security number of each such worker; his or her correct classification; hourly rates of wages paid (including rates of contributions or costs anticipated for bona fide fringe benefits or cash equivalents thereof of the types described in 1(b)(2)(B) of the Davis- Bacon Act); daily and weekly number of hours worked; deductions made; and actual wages paid. Whenever the Secretary of Labor has found under 29 CFR 5.5(a)(1)(iv) that the wages of any laborer or mechanic include the amount of any costs reasonably anticipated in providing benefits under a plan or program described in section 1(b)(2)(B) of the Davis - Bacon Act, the Contractor shall maintain records that show that the commitment to provide such benefits is enforceable, that the plan or program is financially responsible, and that the plan or program has been communicated in writing to the laborers or mechanics affected, and records which show the costs anticipated or the actual costs incurred in providing such benefits. Contractors employing apprentices or trainees under approved programs shall maintain written evidence of the registration of apprenticeship programs and certification of trainee programs, the registration of the apprentices and trainees, and the ratios and w age rates prescribed in the applicable programs.
(ii)(A) The Contractor shall submit weekly for each week in which any contract work is performed a copy of all payrolls to the Federal Aviation Administration if the agency is a party to the contract, but if the agency is not such a party, the Contractor will submit the

payrolls to the applicant, the City, or Owner, as the case may be, for transmission to the Federal Aviation Administration. The payrolls submitted shall set out accurately and completely all of the information required to be maintained under 29 CFR § 5.5(a)(3)(i), except that full social security numbers and home addresses shall not be included on weekly transmittals. Instead the payrolls shall only need to include an individually identifying number for each employee (e.g., the last four digits of the employee’s social security number). The required weekly payroll information may be submitted in any form desired. Optional Form WH–347 is available for this purpose from the Wage and Hour Division Web site at https://www.dol.gov/agencies/whd/government-contracts/construction/payroll-certification or its successor site. The prime contractor is responsible for the submission of copies of payrolls by all subcontractors. Contractors and subcontractors shall maintain the full social security number and current address of each covered worker and shall provide them upon request to the Federal Aviation Administration if the agency is a party to the contract, but if the agency is not such a party, the Contractor will submit them to the applicant, the City, or Owner, as the case may be, for transmission to the Federal Aviation Administration, the Contractor, or the Wage and Hour Division of the Department of Labor for purposes of an investigation or audit of compliance with prevailing wage requirements. It is not a violation of this section for a prime contractor to require a subcontractor to provide addresses and social security numbers to the prime contractor for its own records, without weekly submission to the sponsoring government agency (or the applicant, City, or Owner). (B) Each payroll submitted shall be accompanied by a "Statement of Compliance," signed by the Contractor or subcontractor or his or her agent who pays or supervises the payment of the persons employed under the contract and shall certify the following:
(1) That the payroll for the payroll period contains the information required to be provided under 29 CFR § 5.5(a)(3)(ii), the appropriate information is being maintained under 29 CFR § 5.5 (a)(3)(i), and that such information is correct and complete; (2) That each laborer and mechanic (including each helper, apprentice, and trainee) employed on the contract during the payroll period has been paid the full weekly wages earned, without rebate, either directly or indirectly, and that no deductions have been made either directly or indirectly from the full wages earned, other than permissible deductions as set forth in Regulations, 29 CFR Part 3;
(3) That each laborer or mechanic has been paid not less than the applicable wage rates and fringe benefits or cash equivalents for the classification of work performed, as specified in the applicable wage determination incorporated into the contract. (C) The weekly submission of a properly executed certification set forth on the reverse side of Optional Form WH-347 shall satisfy the requirement for submission of the “Statement of Compliance” required by paragraph (3)(ii)(B) of this section. (D) The falsification of any of the above certifications may subject the Contractor or subcontractor to civil or criminal prosecution under Section 1001 of Title 18 and Section 231 of Title 31 of the United States Code.
(iii) The Contractor or subcontractor shall make the records required under paragraph (3)(i) of this section available for inspection, copying, or transcription by authorized representatives of the City, the Federal Aviation Administration, or the Department of Labor

and shall permit such representatives to interview employees during working hours on the job. If the Contractor or subcontractor fails to submit the required records or to make them available, the Federal agency may, after written notice to the Contractor, the City, applicant, or Owner, take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds. Furthermore, failure to submit the required records upon request or to make such records available may be grounds for debarment action pursuant to 29 CFR § 5.12.

4. Apprentices and Trainees.
(i) Apprentices. Apprentices will be permitted to work at less than the predetermined rate for the work they performed when they are employed pursuant to and individually registered in a bona fide apprenticeship program registered with the U.S. Department of Labor, Employment and Training Administration, Office of Apprenticeship Training, Employer and Labor Services, or with a State Apprenticeship Agency recognized by the Office, or if a person is employed in his or her first 90 days of probationary employment as an apprentice in such an apprenticeship program, who is not individually registered in the program, but who has been certified by the Office of Apprenticeship Training, Employer and Labor Services or a State Apprenticeship Agency (where appropriate) to be eligible for probationary employment as an apprentice. The allowable ratio of apprentices to journeymen on the job site in any craft classification shall not be greater than the ratio permitted to the contractor as to the entire work force under the registered program. Any worker listed on a payroll at an apprentice wage rate, who is not registered or otherwise employed as stated above, shall be paid not less than the applicable wage rate on the wage determination for the classification of work actually performed. In addition, any apprentice performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate on the wage determination for the work actually performed. Where a contractor is performing construction on a project in a locality other than that in which its program is registered, the ratios and wage rates (expressed in percentages of the journeyman’s hourly rate) specified in the Contractor’s or subcontractor’s registered program shall be observed. Every apprentice must be paid at not less than the rate specified in the registered program for the apprentice’s level of progress, expressed as a percentage of the journeymen hourly rate specified in the applicable wage determination.

Apprentices shall be paid fringe benefits in accordance with the provisions of the apprenticeship program. If the apprenticeship program does not specify fringe benefits, apprentices must be paid the full amount of fringe benefits listed on the wage determination for the applicable classification. If the Administrator determines that a different practice prevails for the applicable apprentice classification, fringes shall be paid in accordance with that determination. In the event the Office of Apprenticeship Training, Employer and Labor Services, or a State Apprenticeship Agency recognized by the Office, withdraws approval of an apprenticeship program, the Contractor will no longer be permitted to utilize apprentices at less than the applicable predetermined rate for the work performed until an acceptable program is approved.
(ii) Trainees. Except as provided in 29 CFR § 5.16, trainees will not be permitted to work at less than the predetermined rate for the work performed unless they are employed pursuant to and individually registered in a program which has received prior approval, evidenced by formal certification by the U.S. Department of Labor, Employment and Training

Administration. The ratio of trainees to journeymen on the job site shall not be greater than permitted under the plan approved by the Employment and Training Administration. Every trainee must be paid at not less than the rate specified in the approved program for the trainee’s level of progress, expressed as a percentage of the journeyman hourly rate specified in the applicable wage determination. Trainees shall be paid fringe benefits in accordance with the provisions of the trainee program. If the trainee program does not mention fringe benefits, trainees shall be paid the full amount of fringe benefits listed on the wage determination unless the Administrator of the Wage and Hour Division determines that there is an apprenticeship program associated with the corresponding journeyman wage rate on the wage determination that provides for less than full fringe benefits for apprentices.

Any employee listed on the payroll at a trainee rate that is not registered and participating in a training plan approved by the Employment and Training Administration shall be paid not less than the applicable wage rate on the wage determination for the classification of work actually performed. In addition, any trainee performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate on the wage determination for the work actually performed. In the event the Employment and Training Administration withdraws approval of a training program, the Contractor will no longer be permitted to utilize trainees at less than the applicable predetermined rate for the work performed until an acceptable program is approved.

5. Compliance with Copeland Act Requirements.

The Contractor shall comply with the requirements of 29 CFR Part 3, which are incorporated by reference in this contract.

6. Subcontracts.

The Contractor or subcontractor shall insert in any subcontracts the clauses contained in 29 CFR §§ 5.5(a)(1) through (10) and such other clauses as the Federal Aviation Administration may by appropriate instructions require, and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for the compliance by any subcontractor or lower tier subcontractor with all the contract clauses in 29 CFR § 5.5.

7. Contract Termination: Debarment.

A breach of the contract clauses in paragraph 1 through 10 of this section may be grounds for termination of the contract, and for debarment as a contractor and a subcontractor as provided in 29 CFR § 5.12.

8. Compliance with Davis-Bacon and Related Act Requirements.

All rulings and interpretations of the Davis -Bacon and Related Acts contained in 29 CFR Parts 1, 3, and 5 are herein incorporated by reference in this contract.

9. Disputes Concerning Labor Standards.

Disputes arising out of the labor standards provisions of this contract shall not be subject to the general disputes clause of this contract. Such disputes shall be resolved in accordance with the procedures of the Department of Labor set forth in 29 CFR Parts 5, 6, and 7.

Disputes within the meaning of this clause include disputes between the Contractor (or any

of its subcontractors) and the contracting agency, the U.S. Department of Labor, or the employees or their representatives.

10. Certification of Eligibility.
(i) By entering into this contract, the Contractor certifies that neither it (nor he or she) nor any person or firm who has an interest in the Contractor’s firm is a person or firm ineligible to be awarded Government contracts by virtue of section 3(a) of the Davis-Bacon Act or 29 CFR § 5.12(a)(1).
(ii) No part of this contract shall be subcontracted to any person or firm ineligible for award of a Government contract by virtue of section 3(a) of the Davis -Bacon Act or 29 CFR §

5.12(a)(1).
(iii) The penalty for making false statements is prescribed in the U.S. Criminal Code, 18 USC § 1001.

Reference: 2 CFR Part 200, Appendix II(D); 29 CFR Part 5; 49 USC § 47112(b); 40 USC §§ 3141-3144, 3146, and 3147

FAA – 10 Debarment and Suspension
APPLICABILITY - This requirement applies to covered transactions, which are defined in 2 CFR part 180 (Subpart B). AIP funded contracts are non- procurement transactions, as defined by 2 CFR § 180.970. Covered transactions include any AIP -funded contract, regardless of tier, that is awarded by a contractor, subcontractor, supplier, consultant, or its agent or representative in any transaction, if the amount of the contract is expected to equal or exceed $25,000. This includes contracts associated with land acquisition projects.

REQUIREMENT -
A11.3.1 Bidder or Offeror Certification
By submitting a bid/proposal under the solicitation for this contract, the Contractor must have certified that neither it nor its principals are presently debarred or suspended by any Federal department or agency from participation in this transaction.

A11.3.2 Lower Tier Contract Certification

CERTIFICATION OF LOWER TIER CONTRACTORS REGARDING DEBARMENT The successful bidder, by administering each lower tier subcontract that exceeds $25,000 as a “covered transaction”, must confirm each lower tier participant of a “covered transaction” under the project is not presently debarred or otherwise disqualified from participation in this federally assisted project. The successful bidder will accomplish this by:

1. 1. Checking the System for Award Management at website: http://www.sam.gov.

2. 2. Collecting a certification statement similar to the Certification of Offerer /Bidder Regarding Debarment, above.

3. 3. Inserting a clause or condition in the covered transaction with the lower tier contract.

If the Federal Aviation Administration later determines that a lower tier participant failed to disclose to a higher tier participant that it was excluded or disqualified at the time it entered the covered transaction, the FAA may pursue any available remedies, including suspension and debarment of the non-compliant participant.

Reference: 2 CFR part 180 (Subpart B), 2 CFR part 200 Appendix II(H), 2 CFR Part 1200, DOT Order 4200.5; Executive Orders 12549 and 12689

FAA – 11 Disadvantaged Business Enterprise
APPLICABILITY – all contracts with Airports that have a DBE program on file with the FAA.

Contract Assurance (§ 26.13) –
The Contractor or subcontractor shall not discriminate on the basis of race, color, national origin, or sex in the performance of this contract. The Contractor shall carry out applicable requirements of 49 CFR part 26 in the award and administration of Department of Transportation-assisted contracts. Failure by the Contractor to carry out these requirements is a material breach of this contract, which may result in the termination of this contract or such other remedy as the City deems appropriate, which may include, but is not limited to:
1) Withholding monthly progress payments;
2) Assessing sanctions;
3) Liquidated damages; and/or
4) Disqualifying the Contractor from future bidding as non-responsible.

Prompt Payment (§26.29) – The prime contractor agrees to pay each subcontractor under this prime contract for satisfactory performance of its contract no later than [10] days from the receipt of each payment the prime contractor receives from [the City]. The prime contractor agrees further to return retainage payments to each subcontractor within [30 days] days after the subcontractor’s work is satisfactorily completed. Any delay or postponement of payment from the above referenced time frame may occur only for good cause following written approval of the [City]. This clause applies to both DBE and non-DBE subcontractors.

FAA – 12 Distracted Driving
APPLICABILITY - contracts that exceed the micro-purchase threshold of 2 CFR § 200.320 (currently set at $10,000).

REQUIREMENT -

TEXTING WHEN DRIVING
In accordance with Executive Order 13513, “Federal Leadership on Reducing Text Messaging While Driving”, (10/1/2009) and DOT Order 3902.10, “Text Messaging While Driving”, (12/30/2009), the Federal Aviation Administration encourages recipients of Federal grant funds to adopt and enforce safety policies that decrease crashes by distracted drivers, including policies to ban text messaging while driving when performing work related to a grant or subgrant.

In support of this initiative, the City encourages the Contractor to promote policies and initiatives for its employees and other work personnel that decrease crashes by distracted drivers, including policies that ban text messaging while driving motor vehicles while performing work activities associated with the project. The Contractor must include the substance of this clause in all sub-tier contracts exceeding $15 ,000 that involve driving a motor vehicle in performance of work activities associated with the project.

Reference: Executive Order 13513, DOT Order 3902.10

FAA – 13 Prohibition on Certain Telecommunications and Video Surveillance Services and Equipment
APPLICABILITY - all AIP funded contracts and lower-tier contracts.

REQUIREMENT -
Contractor and Subcontractor agree to comply with mandatory standards and policies relating to use and procurement of certain telecommunications and video surveillance services or equipment in compliance with the National Defense Authorization Act [Public Law 115-232 § 889(f)(1)].

Reference: 2 CFR § 200, Appendix II(K); 2 CFR § 200.216

FAA – 14 Drug Free Workplace Requirements
APPLICABILITY - This provision applies to all AIP funded projects, but not to the contracts between the City and a contractor, subcontractors, suppliers, or subgrantees.

The Drug-Free Workplace Act of 1988 requires some Federal contractors and all Federal grantees to agree that they will provide drug-free workplaces as a condition of receiving a contract or grant from a Federal agency. The Act does not apply to contractors, subcontractors, or subgrantees, although the Federal grantees workplace may be where the contractors, subcontractors, or subgrantees are working.

Reference: 49 CFR part 32, Drug-Free Workplace Act of 1988 (41 U.S.C. 701 et seq., as amended)

FAA – 15 Federal Fair Labor Standards Act
APPLICABILITY – Contract Types – Per the Department of Labor, all employees of certain enterprises having workers engaged in interstate commerce; producing goods for interstate commerce; or handling, selling, or otherwise working on goods or materials that have been moved in or produced for such commerce by any person are covered by the FLSA.

All consultants, sub-consultants, contractors, and subcontractors employed under this federally assisted project must comply with the FLSA.

Professional Services – 29 CFR § 213 exempts employees in a bona fide executive, administrative or professional capacity. Because professional firms employ individuals that are not covered by this exemption, the agreement with a professional services firm must include the FLSA provision.

REQUIREMENT -
The provisions of 29 CFR part 201, the Federal Fair Labor Standards Act (FLSA), are incorporated by reference with the same force and effect as if given in full text. The FLSA sets minimum wage, overtime pay, recordkeeping, and child labor standards for full and part-time workers.

The Contractor has full responsibility to monitor compliance to the referenced statute or regulation. The Contractor must address any claims or disputes that arise from this requirement directly with the U.S. Department of Labor – Wage and Hour Division.

Reference: 29 USC § 201, et seq; 2 CFR § 200.430

FAA – 16 Lobbying and Influencing Federal Employees
APPLICABILITY- all contracts exceeding $100,000.

REQUIREMENT -
Consultants and contractors that apply or bid for an award of $100,000 or more must have certified that it will not and has not used Federal appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant, or another award covered by 31 USC §1352. Each tier must also disclose any lobbying with non-Federal funds that takes place in connection with obtaining any Federal award.

For an award over $100,00, the bidder or offeror certifies by signing and submitting this bid or proposal, to the best of his or her knowledge and belief, that:
(1) No Federal appropriated funds have been paid or will be paid, by or on behalf of the bidder or offeror, to any person for influencing or attempting to influence an officer or employee of an agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement. (2) If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a M ember of Congress in connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form -LLL, “Disclosure Form to Report Lobbying,” in accordance with its instructions.
(3) The undersigned shall require that the language of this certification be included in the award documents for all sub-awards at all tiers (including subcontracts, sub-grants, and contracts under grants, loans, and cooperative agreements) and that all sub-recipients shall certify and disclose accordingly.

This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by section 1352, title 31, U.S. Code. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure.

Reference: 31 USC § 1352 – Byrd Anti-Lobbying Amendment, 2 CFR part 200, Appendix II(I), 49 CFR part 20, Appendix A

FAA – 17 Occupational Safety and Health Act
APPLICABILITY – Contract Types – All contracts and subcontracts must comply with the Occupational Safety and Health Act of 1970 (OSH). The U.S. Department of Labor Occupational Safety and Health Administration (OSHA) oversees the workplace health and safety standards wage provisions from OSH.

REQUIREMENT -
All contracts and subcontracts that result from this solicitation incorporate by reference the requirements of 29 CFR Part 1910 with the same force and effect as if given in full text. The employer must provide a work environment that is free from recogni zed hazards that may cause death or serious physical harm to the employee. The employer retains full responsibility to monitor its compliance and their subcontractor’s compliance with the applicable requirements of the Occupational Safety and Health Act of 1970 (29 CFR Part 1910). The employer must address any claims or disputes that pertain to a referenced requirement directly with the U.S. Department of Labor – Occupational Safety and Health Administration.

Reference: 29 CFR part 1910

FAA – 18 Procurement of Recovered Materials
APPLICABILITY – Contract Types – This provision applies to any contracts that include procurement of products designated in subpart B of 40 CFR part 247 where the purchase price of the item exceeds $10,000 or the value of the quantity acquired by the preceding fiscal year exceeded $10,000.

Construction and Equipment – all construction and equipment projects.

Professional Services and Property – if the agreement includes procurement of a product that exceeds $10,000.

REQUIREMENT -
Contractor and subcontractor agree to comply with Section 6002 of the Solid Waste Disposal Act, as amended by the Resource Conservation and Recovery Act, and the regulatory provisions of 40 CFR Part 247. In the performance of this contract and to the extent practicable, the Contractor and subcontractors are to use products containing the highest percentage of recovered materials for items designated by the Environmental Protection Agency (EPA) under 40 CFR Part 247 whenever:
1) The contract requires procurement of $10,000 or more of a designated item during the fiscal year; or
2) The contractor has procured $10,000 or more of a designated item using Federal funding during the previous fiscal year.

The list of EPA -designated items is available at www.epa.gov/smm/comprehensive- procurement-guidelines-construction-products.

Section 6002(c) establishes exceptions to the preference for recovery of EPA -designated products if the contractor can demonstrate the item is:
a) Not reasonably available within a timeframe providing for compliance with the contract performance schedule;
b) Fails to meet reasonable contract performance requirements; or c) Is only available at an unreasonable price.

Reference: 2 CFR § 200.323, 2 CFR Part 200, Appendix II (J); 40 CFR part 247, 42 USC § 6901, et seq (Resource Conservation and Recovery Act)

FAA – 19 Right to Inventions
APPLICABILITY – Contract Types – This provision applies to all contracts and subcontracts with small business firms or nonprofit organizations that include performance of experimental, developmental, or research work. This clause is not applicable to construction, equipment, or professi onal service contracts unless the contract includes experimental, developmental, or research work.

REQUIREMENT -
Contracts or agreements that include the performance of experimental, developmental, or research work must provide for the rights of the Federal Government and the City in any resulting invention as established by 37 CFR part 401, Rights to Inventions Made by Non- profit Organizations and Small Business Firms under Government Grants, Contracts, and Cooperative Agreements. This contract incorporates by reference the patent and inventions rights as specified within 37 CFR §401.14. Contractor must include thi s requirement in all sub-tier contracts involving experimental, developmental, or research work.

Reference: 2 CFR § 200, Appendix II(F), 37 CFR 401

FAA - 20 Seismic Safety
APPLICABILITY – Contract Types – This provision applies to construction of new buildings and additions to existing buildings financed in whole or in part through the Airport Improvement Program.

Professional Services– any contract involved in the construction of new buildings or structural addition to existing buildings.

Construction – any contract involved in the construction of new buildings or structural addition to existing buildings.

Equipment – if the project involves construction or structural addition to a building such as an electrical vault project to accommodate or install equipment.

Land – This provision will not typically apply to a property/land project.

REQUIREMENT -
A20.3.1 Professional Service Agreements for Design

SEISMIC SAFETY
In the performance of design services, the Consultant agrees to furnish a building design and associated construction specification that conform to a building code standard that provides a level of seismic safety substantially equivalent to standards as es tablished by the National Earthquake Hazards Reduction Program (NEHRP). Local building codes that model their building code after the current version of the International Building Code (IBC) meet the NEHRP equivalency level for seismic safety. At the conclusion of the design services, the Consultant agrees to furnish the Owner a “certification of compliance” that attests conformance of the building design and the construction specifications with the seismic standards of NEHRP or an equivalent building code.

A20.3.2 Construction Contracts

SEISMIC SAFETY
The Contractor agrees to ensure that all work performed under this contract, including work performed by subcontractors, conforms to a building code standard that provides a level of seismic safety substantially equivalent to standards established by the National Earthquake Hazards Reduction Program (NEHRP). Local building codes that model their code after the current version of the International Building Code (IBC) meet the NEHRP equivalency level for seismic safety.

Reference: 49 CFR Part 41

FAA – 21 Tax Delinquency and Felony Conviction
APPLICABILITY – This provision applies to all contracts funded in whole or part with AIP.

REQUIREMENT -
The applicant must complete the following two certification statements. The applicant must indicate its current status as it relates to tax delinquency and felony conviction by inserting a checkmark in the space following the applicable response. The applicant agrees that, if awarded a contract resulting from this solicitation, it will incorporate this provision for certification in all lower tier subcontracts.

Certifications

1. The applicant represents that it is ( ) is not ( ) a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability.

2. The applicant represents that it is ( ) is not ( ) a corporation that was convicted of a criminal violation under any Federal law within the preceding 24 months.

Note
If an applicant responds in the affirmative to either of the above representations, the applicant is ineligible to receive an award unless the Sponsor has received notification from the agency suspension and debarment official (SDO) that the SDO has considered suspension or debarment and determined that further action is not required to protect the Government’s interests. The applicant therefore must provide information to the owner about its tax liability or conviction to the Owner, who will then notify the FAA Airports District Office, which will then notify the agency’s SDO to facilitate completion of the required considerations before award decisions are made.

Term Definitions
Felony conviction: Felony conviction means a conviction within the preceding twenty four (24) months of a felony criminal violation under any Federal law and includes conviction of an offense defined in a section of the U.S. Code that specifically classifies the offense as a felony and conviction of an offense that is classified as a felony under 18 USC § 3559.

Tax Delinquency: A tax delinquency is any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted, or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability.

Reference: Sections 8113 of the Consolidated Appropriations Act, 2022 (Public Law 117- 103), and similar provisions in subsequent appropriations acts.

DOT Order 4200.6 – Appropriations Act Requirements for Procurement and Non- Procurement Regarding Tax Delinquency and Felony Convictions

FAA – 22 Termination of Contract
APPLICABILITY – All contracts and subcontracts in excess of $10,000.

REQUIREMENT -
See Section 3.2 of the Agreement.

Reference: 2 CFR § 200 Appendix II(B), FAA Advisory Circular 150/5370-10, Section 80-09

FAA – 23 Trade Restriction Certification
APPLICABILITY – all AIP funded projects.

REQUIREMENT -

TRADE RESTRICTION CERTIFICATION
By accepting this contract the Contractor certifies the following statements are true – 1) is not owned or controlled by one or more citizens of a foreign country included in the list of countries that discriminate against U.S. firms as published by the Office of the United States Trade Representative (USTR);
2) has not knowingly entered into any contract or subcontract for this project with a person that is a citizen or national of a foreign country included on the list of countries that discriminate against U.S. firms as published by the USTR; and
3) has not entered into any subcontract for any product to be used on the Federal project that is produced in a foreign country included on the list of countries that discriminate against U.S. firms published by the USTR.

This certification concerns a matter within the jurisdiction of an agency of the United States of America and the making of a false, fictitious, or fraudulent certification may render the maker subject to prosecution under Title 18 USC Section 1001.

The Contractor must provide immediate written notice to the City if the Contractor learns that its certification or that of a subcontractor was erroneous when submitted or has become erroneous by reason of changed circumstances. The Contractor must require subcontractors provide immediate written notice to the Contractor if at any time it learns that its certification was erroneous by reason of changed circumstances.

Unless the restrictions of this clause are waived by the Secretary of Transportation in accordance with 49 CFR 30.17, no contract shall be awarded to an Offeror or subcontractor:
1) who is owned or controlled by one or more citizens or nationals of a foreign country included on the list of countries that discriminate against U.S. firms published by the USTR or 2) whose subcontractors are owned or controlled by one or more citizens or nationals of a foreign country on such USTR list or
3) who incorporates in the public works project any product of a foreign country on such USTR list.

Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by this provision. The knowledge and information of a contractor is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

The Contractor agrees it will incorporate this provision for certification without modification in all lower tier subcontracts. The Contractor may rely on the certification of a prospective subcontractor that it is not a firm from a foreign country included on the list of countries that discriminate against

U.S. firms as published by USTR, unless the Contractor has knowledge that the certification is erroneous.

This certification is a material representation of fact upon which reliance was placed when making an award. If it is later determined that the Contractor or subcontractor knowingly rendered an erroneous certification, the Federal Aviation Administration (FAA) may direct through the City cancellation of the contract or subcontract for default at no cost to the City or the FAA.

Reference: 49 USC § 50104, 49 CFR part 30

FAA – 24 Veteran’s Preference
APPLICABILITY – This provision applies to all AIP funded projects that involve labor to carry out the project. This preference, which excludes executive, administrative, and supervisory positions, applies to covered veterans [as defined under § 47112(c)] only when they are readily available and qualified to accomplish the work required by the project.

REQUIREMENT -
In the employment of labor (excluding executive, administrative, and supervisory positions), the Contractor and all sub-tier contractors must give preference to covered veterans as defined within Title 49 United States Code Section 47112. Covered veterans include Vietnam-era veterans, Persian Gulf veterans, Afghanistan -Iraq war veterans, disabled veterans, and small business concerns (as defined by 15 USC 632) owned and controlled by disabled veterans. This preference only applies when there are covered veterans readily available and qualified to perform the work to which the employment relates.

Reference: 49 USC § 47112(c)

FAA – 25 Domestic Preferences for Procurements
APPLICABILITY – all contracts and Purchase orders for work or products under the grant.

REQUIREMENT -
The Contractor certifies by signing and submitting its bid or proposal that, to the greatest extent practicable, the Contractor has provided a preference for the purchase, acquisition, or use of goods, products, or materials produced in the United States (including, but not limited to, iron, aluminum, steel, cement, and other manufactured products) in compliance with 2 CFR § 200.322.

Reference: 2 CFR § 200.322; 2 CFR Part 200, Appendix II(L)

FAA – 26 Prohibition of Covered Unmanned Aircraft Systems (UAS) APPLICABILITY – all AIP-funded contracts and lower tier contracts.

REQUIREMENT -
The Contractor certifies that they are aware of and comply with relevant Federal statutes and regulations, including those from the Federal Aviation Administration (FAA), for operating unmanned aircraft systems (UAS) in accordance, and in compliance with all related requirements in the FAA Reauthorization Act of 2024 (Public Law 118-63), section 936 (49 U.S.C. § 44801 note).

Contractor warrants that all UAS operations will be conducted in full compliance with all applicable Federal Aviation Administration (FAA) regulations, including but not limited to 14 CFR Part 107, and any other applicable local, state, or Federal laws and regulations.

Sponsors and subgrant recipients cannot use AIP grant funds to enter into, extend, or renew a contract related to covered unmanned aircraft systems (UAS). This includes both procurement and operational contracts, as well as contracts with entities that operate such systems.

The term “Covered UAS” means a small unmanned aircraft, an unmanned aircraft, and unmanned aircraft system, or the associated elements of such aircraft and aircraft systems related to the collection and transmission of sensitive information (consisting of communication links and the components that control the unmanned aircraft) that enable the operator to operate the aircraft in the National Airspace System which is manufactured or assembled by a covered foreign entity; and an unmanned aircraft detection system or counter- UAS system that is manufactured or assembled by a covered foreign entity. These covered foreign entities include:
(a) The People’s Republic of China.
(b) The Russian Federation.
(c) The Islamic Republic of Iran.
(d) The Democratic People’s Republic of Korea.
(e) The Bolivarian Republic of Venezuela.
(f) The Republic of Cuba.
(g) Any other country the Secretary determines necessary.

Reference: FAA Reauthorization Act of 2024 (Public Law 118-63), Section 936 49 U.S.C. § 44801 note