Contract Change Order No.3
Project Title City of Placentia FY 2020-21 Roadway Rehabilitation Project, # 1102 Owner: Cly of Flacon. Con Lt or: R J Noble Company
You are hereby directed to make the herein described changes from the pians and specifications or to do the following described work not included in the plans and specifications on this contract:
Description of work done, estimate of quantities and prices to be paid. 1 This Change Order provides:
a) Extra work and credits identified in Exhibit A
$ 45,054.08
2 This Change Order came about from:
a)
Extra work performed
3 Action to be taken:
a) The Contractor was directed to provide a lump sum price for this change. 4 Compensation
a) Adjustment of Line Items exceeding 25%
b) Extra work $ 45,054.08
d) Credits $ 6,873.30
Total $ 38,180.78
5 Contract Time Extension
a) 5 working days
In addition to work specified in the bid specifications, this change order includes all extra work, field adjustments and credits. This work is an Contractor initiated change and includes all labor, equipment, materials, and supervision and Adminstration.
CHANGE TO CONTRACT COST: CHANGE TO CONTRACT TIME:
Contract Amount: $ 3,112,796.95
Previous CCOs: $ 324,205.75
Adjustment of Line
Items Exceeding 25% $ 45,054.08
Total Extra Work $ 45,054.08
Total Field Adjustments $
Total Credits $ 6,873.30
Changes in Line Items: $ 38,180.78
Current Contract price: $ 3,475,183.48
Prepared by:
Kevin Koura, Public Works Inspector, City of Placentia
Recommended:
Masoud Sepahi, City Engineer, City Of Placentia
Recommended:
Approved by:
Luis Estevez, Deputy City Administrator, City Of Placentia Damien R. Arrula, City Administrrator, City Of Placentia We, the undersigned contractor, have given careful consideration tot e proposed and hereby agree, if this proposal, is approved, that we will provide all equipment, furnish all materials, e .fes otherwise be shown above
Accepted:
Francis Garcia / Project Manager `r��r .2/17/2022
if the Contractor does not sign acceptance of this ofd _ , atte ted to the requirements of the specifications as to proceeding with the ordered work and filing a written protest within the time therein specified.
ATTACHMENT 2
CCO No. 3 Exhibit 'A'
Project Title: FY 2020-21 Roadway Rehabilitation Project, #1102 Owner:
No.
City of Placentia Contractor: R J Noble
Actual
Description Bid $$ Comments CREDIT EXTRA
19 Striping modifications on Melrose & Madison Revisions to striping plan $2,788.56 1 s $2.788.50
21 Striping modifications on Richfield 1 s $15,648 25 Revisions to striping plan $15,648.25 Repair T -Lock liner in OCSD manhole OCSD requirements $6.050.OD 22 1 s $6.050.00
23 Stand-by trucking 1 s $6,037.50 Delay caused by unforeseen condition $6.037-50 24 delay , labor and equipment 1 s $9.244.11 Delay caused by unforeseen condition $9.244 11
deductions for bike lane at Chapman
26 Credit for Chapman striping deductions 1 s -$6.873 30 and Orangethorp -$6.873.30 mast arm modification to move signal head
27 Cost for mast arm modification at Orangethorp and Melrose 1 is $5.285 72 - $5.285-72 Sum of Line Item Adjustments $
Cost of Line Item adiustments $
Change in Contract Cost
(6.873 301
38.180.78
$38,180.78
ATTACHMENT 2
$0.00
$0.001
50.00 50.00
50.00 545,054.081