Contract Change Order No. 10
Project Title: Crowther Sewer Line Project
Owner: city of Piancentia Contractor: Kana Pipeline, Inc.
You are hereby directed to make the herein described changes from the plans and specifications or to do the following described work not included in the plans and specifications on this contract:
Description of work done, estimate of quantities and prices to be paid. 1 This Change Order provides:
a) Change to contract amount per exhibit A.
2 This Change Order came about from:
a)
This change order is to adjust the final contract amount, by including, all previous change orders Nos. 1- 9, the final adjustments on the bid items, Liquidated Damages for delays, caused by Kana and credits due to the City for items that were deleted from the project. 3 Action to be taken:
a)
This change order adjusts the final contract amount per the following:
4 Compensation
a) Adjustment of Line Items exceeding 25%
b) Extra work/quantity overages
d) Credits for Work Deleted From Scope
e) Liquidated Damages
TOTAL THIS CHANGE ORDER NO.10
5 Contract Time Extension
a) 0
$ 209,027.00
$ (48,043.14)
$ (348,000.00)
-$187,016.14
In addition to work specified in the bid specifications, this change order includes all extra work, field adjustments and credits. This work is an Contractor initiated change and includes all labor, equipment, materials, and supervision and Adminstration.
CHANGE TO CONTRACT COST: CHANGE TO CONTRACT TIME:
Contract Amount: $ 4,696,973.63
Previous CCOs: $ 335,782.13
Adjustment of Line
Items Exceeding 25% $
Total CO#10 $ (187,016.14)
Total Extra Work/Overages $ 209,027.00
Credit for Work Not Needed $ (48,043.14)
Liquidated Damages $ (348,000.00)
Current Contract price: $ 4,845,739.62
Prepared by:
Recommended:
Recommended:
Approved by:
None
Masoud Sepahi
Chris Tanio, Deputy Director of Public Works/City Engineer Luis Estevez, Deputy City Administrator, City Of Placentia Damien R. Arrula, City Administrrator, City Of Placentia We, the undersigned contractor, have given careful consideration to the change proposed and hereby agree, if this proposal, is approved, that we will provide all equipment, furnish all materials, except as may otherwise be e
shown above
Accepted:
If the Contractor does not sign acceptance of this order, his attention is directed to the requirements of the specifications as to proceeding with the ordered work and filing a written protest within the time therein specified.