CITY OF PLACENTIA
PROFESSIONAL SERVICES AGREEMENT
WITH PLACEWORKS, INC
THIS AGREEMENT is made and entered into this 21st day of May, 2024 ("Effective Date"), by and between the CITY OF PLACENTIA, a municipal corporation ("City"), and PLACEWORKS, INC., a California S -Corporation ("Consultant").
WITNESSETH:
A. WHEREAS, City proposes to utilize the services of Consultant as an independent contractor to prepare the City of Placentia Chapman Corridor Plan and related CEQA documents, as more fully described herein; and
B. WHEREAS, Consultant represents that it has that degree of specialized expertise contemplated within California Government Code Section 37103, and holds all necessary licenses to practice and perform the services herein contemplated; and C. WHEREAS, City and Consultant desire to contract for the specific services described in Exhibit "A" (the "Project") and desire to set forth their rights, duties, and liabilities in connection with the services to be performed; and
D. WHEREAS, no official or employee of City has a financial interest, within the provisions of Sections 1090-1092 of the California Government Code, in the subject matter of this Agreement.
NOW, THEREFORE, for and in consideration of the mutual covenants and conditions contained herein, the parties hereby agree as follows:
1.0. SERVICES PROVIDED BY CONSULTANT
1.1. Scope of Services. Consultant shall provide the professional services described in the Consultant's Proposal ("Proposal"), attached hereto as Exhibit "A" and incorporated herein by this reference.
1.2. Professional Practices. All professional services to be provided by Consultant pursuant to this Agreement shall be provided by personnel experienced in their respective fields and in a manner consistent with the standards of care, diligence and skill ordinarily exercised by professional consultants in similar fields and circumstances in accordance with sound professional practices. Consultant also warrants that it is familiar with all laws that may affect its performance of this Agreement and shall advise City of any changes in any laws that may affect Consultant's performance of this Agreement. Consultant shall keep itself informed of State and Federal laws and regulations which in any manner affect those employed by it or in any way affect the performance of its service pursuant to this Agreement. The Consultant shall at all times observe and comply with all such laws and regulations. Officers and employees shall not be liable at law or in equity occasioned by failure of the Consultant to comply with this Section.
1.3. Performance to Satisfaction of City. Consultant agrees to perform all the work to the complete satisfaction of the City and within the hereinafter specified. Evaluations of the work will be done by the City Administrator or his or her designee. If the quality of work is not satisfactory, City in its discretion has the right to:
(a) Meet with Consultant to review the quality of the work and resolve the
matters of concern;
(b) Require Consultant to repeat the work at no additional fee until it is satisfactory; and/or
(c) Terminate the Agreement as hereinafter set forth.
1.4. Warranty. Consultant warrants that it shall perform the services required by this Agreement in compliance with all applicable Federal and California employment laws, including, but not limited to, those laws related to minimum hours and wages; occupational health and safety; fair employment and employment practices; workers' compensation insurance and safety in employment; and all other Federal, State, and local laws and ordinances applicable to the services required under this Agreement. Consultant warrants that it is not suspended or debarred from doing business with the United States government and can legally be paid from federal funds. Consultant shall indemnify and hold harmless City from and against all claims, demands, payments, suits, actions, proceedings, and judgments of every nature and description including attorneys' fees and costs, presented, brought, or recovered against City for, or on account of any liability under any of the above-mentioned laws, which may be incurred by reason of Consultant's performance under this Agreement.
1.5. Non-discrimination. In performing this Agreement, Consultant shall not engage in, nor permit its agents to engage in, discrimination in employment of persons because of their race, religion, color, national origin, ancestry, age, physical handicap, medical condition, marital status, sexual gender, or sexual orientation, except as permitted pursuant to Section 12940 of the Government Code. Such actions shall include, but not be limited to the following: employment, upgrading, demotion or transfer, recruitment or recruitment advertising, layoff or termination, rates of pay, or other forms of compensation and selection for training, including apprenticeship.
Consultant agrees to post in conspicuous places, available to employees and applicants for employment, a notice setting forth provisions of this non-discrimination clause.
Consultant shall, in all solicitations and advertisements for employees placed by, or on behalf of Consultant shall state that all qualified applicants will receive consideration for employment without regard to age, race, color, religion, sex, marital status, national origin, or mental or physical disability. Consultant shall cause the paragraphs contained in this Section to be inserted in all subcontracts for any work covered by the Agreement, provided that the foregoing provisions shall not apply to subcontracts for standard commercial supplies or raw materials.
1.6. Non -Exclusive Agreement. Consultant acknowledges that City may enter into agreements with other consultants for services similar to the services that are subject to this Agreement or may have its own employees perform services similar to those services contemplated by this Agreement.
1.7. Delegation and Assignment. This is a personal service contract, and the duties set forth herein shall not be delegated or assigned to any person or entity without the prior written consent of City. Consultant may engage a subcontractor(s) as permitted by law and may employ other personnel to perform services contemplated by this Agreement at Consultant's sole cost and expense. All insurance requirements contained in this Agreement are independently applicable to any and all subcontractors that Consultant may engage during the term of this Agreement.
2 [Placeworks, Inc.]
Rev. 01/2024
1.8. Confidentiality. Employees of Consultant in the course of their duties may have access to financial, accounting, statistical, and personnel data of private individuals and employees of City. Consultant covenants that all data, documents, discussion, or other information developed or received by Consultant or provided for performance of this Agreement are deemed confidential and shall not be disclosed by Consultant without written authorization by City. City shall grant such authorization if disclosure is required by law. All City data shall be returned to City upon the termination of this Agreement. Consultant's covenant under this Section shall survive the termination of this Agreement.
2.0. COMPENSATION AND BILLING
2.1. Compensation. Consultant shall be paid in accordance with the fee schedule set forth in Exhibit "A". Consultant's total compensation shall not exceed one hundred twenty four thousand six hundred sixty one Dollars ($124,661), which represents a scope of work cost of one hundred four thousand six hundred sixty one dollars ($104,661) + twenty thousand dollars ($20,000) contingency, unless authorized herein.
2.2. Additional Services. Consultant shall not receive compensation for any services provided outside the scope of services specified in the Consultant's Proposal or which is inconsistent with or in violation of the provisions of this Agreement unless the City or the Project Manager for this Project, prior to Consultant performing the additional services, approves such additional services in writing. It is specifically understood that oral requests and/or approvals of such additional services or additional compensation shall be barred and are unenforceable.
Should the City request in writing additional services that increase the hereinabove described "Scope of Services", an additional fee based upon the Consultant's standard hourly rates shall be paid to the Consultant for such additional services. Such increase in additional fees shall be limited to 10% of the total contract sum. The City Administrator is authorized to approve a Change Order for such additional services. Where the original contract is $40,000.00 or less, City Council approval shall be required prior to any increase bringing the total compensation to more than $40,000.00.
2.3. Method of Billing.. Consultant may submit invoices to the City for approval on a progress basis, but no more often than two times a month. Said invoice shall be based on the total of all Consultant's services which have been completed to City's sole satisfaction. City shall pay Consultant's invoice within forty-five (45) days from the date City receives said invoice. Each invoice shall describe in detail the services performed, the date of performance, and the associated time for completion. Any additional services approved and performed pursuant to this Agreement shall be designated as "Additional Services" and shall identify the number of the authorized change order, where applicable, on all invoices.
2.4. Records and Audits. Records of Consultant's services relating to this Agreement shall be maintained in accordance with generally recognized accounting principles and shall be made available to City or its Project Manager for inspection and/or audit at mutually convenient times for a period of three (3) years from the Effective Date.
3.0. TIME OF PERFORMANCE
3.1. Commencement and Completion of Work. The professional services to be performed pursuant to this Agreement shall commence within five (5) days from the Effective Date of this Agreement. Said services shall be performed in strict compliance with the Project Schedule 3 [Placeworks, Inc.]
Rev. 01/2024
approved by City as set forth in Exhibit "A".
3.2. Excusable Delays. Neither party shall be responsible for delays or lack of performance resulting from acts beyond the reasonable control of the party or parties. Such acts shall include, but not be limited to, acts of God, fire, strikes, material shortages, compliance with laws or regulations, riots, acts of war, or any other conditions beyond the reasonable control of a party. If a delay beyond the control of the Consultant is encountered, a time extension may be mutually agreed upon in writing by the City and the Consultant. The Consultant shall present documentation satisfactory to the City to substantiate any request for a time extension.
4.0. TERM AND TERMINATION
4.1. Term. This Agreement shall commence on the Effective Date and continue for a period of 12 months, ending on May 21, 2025 unless previously terminated as provided herein or as otherwise agreed to in writing by the parties.
4.2. Notice of Termination. The City reserves and has the right and privilege of canceling, suspending, or abandoning the execution of all or any part of the work contemplated by this Agreement, with or without cause, at any time, by providing at least fifteen (15) days prior written notice to Consultant. The termination of this Agreement shall be deemed effective upon receipt of the notice of termination. In the event of such termination, Consultant shall immediately stop rendering services under this Agreement unless directed otherwise by the City. If the City suspends, terminates, or abandons a portion of this Agreement such suspension, termination, or abandonment shall not make void or invalidate the remainder of this Agreement.
If the Consultant defaults in the performance of any of the terms or conditions of this Agreement, it shall have ten (10) days after service upon it of written notice of such default in which to cure the default by rendering a satisfactory performance. In the event that the Consultant fails to cure its default within such period of time, the City shall have the right, notwithstanding any other provision of this Agreement, to terminate this Agreement without further notice and without prejudice to any other remedy to which it may be entitled at law, in equity or under this Agreement.
The City shall have the right, notwithstanding any other provisions of this Agreement, to terminate this Agreement, at its option and without prejudice to any other remedy to which it may be entitled at law, in equity or under this Agreement, immediately upon service of written notice of termination on the Consultant, if the latter should:
a. Be adjudged a bankrupt;
b. Become insolvent or have a receiver of its assets or property appointed because of insolvency;
c. Make a general assignment for the benefit of creditors; d. Default in the performance of any obligation or payment of any indebtedness under this Agreement;
e. Suffer any judgment against it to remain unsatisfied or unbonded of record for thirty (30) days or longer; or
4 [Placeworks, Inc.]
Rev. 01/2024
f. Institute or suffer to be instituted any procedures for reorganization or rearrangement of its affairs.
4.3. Compensation. In the event of termination, City shall pay Consultant for reasonable costs incurred and professional services satisfactorily performed up to and including the date of City's written notice of termination within thirty-five (35) days after service of the notice of termination. Compensation for work in progress shall be prorated based on the percentage of work completed as of the effective date of termination in accordance with the fees set forth herein.
In ascertaining the professional services actually rendered hereunder up to the effective date of termination of this Agreement, consideration shall be given to both completed work and work in progress, to complete and incomplete drawings, and to other documents pertaining to the services contemplated herein whether delivered to the City or in the possession of the Consultant. City shall not be liable for any claim of lost profits.
4.4. Documents. In the event of termination of this Agreement, all documents prepared by Consultant in its performance of this Agreement including, but not limited to, finished or unfinished design, development and construction documents, data studies, drawings, maps, and reports, shall be delivered to the City within ten (10) days of delivery of termination notice to Consultant, at no cost to City. Any use of uncompleted documents without specific written authorization from Consultant shall be at City's sole risk and without liability or legal expense to Consultant.
5.0. INSURANCE
5.1. Insurance. The Consultant and all subcontractors, if any, shall procure and maintain, at its sole cost and expense, in a form and content satisfactory to City, during the entire term of this Agreement, including any extension thereof, insurance as set forth in Exhibit "B" attached hereto and incorporated herein by this reference.
Neither the City nor any of its officers, officials, agents, employees, or volunteers makes any representation that the types of insurance and the limits specified to be carried by Consultant under this Agreement are adequate to protect Consultant. If Consultant believes that any such insurance coverage is insufficient, Consultant shall provide, at its own expense, such additional insurance as Consultant deems adequate.
5.2. Deductible or Self -Insured Retention. If any of such policies provide for a deductible or self-insured retention to provide such coverage, the amount of such deductible or self-insured retention shall be approved in advance by City. No policy of insurance issued as to which the City is an additional insured shall contain a provision which requires that no insured except the named insured can satisfy any such deductible or self-insured retention.
5.3. Certificates of Insurance. Consultant shall provide to City certificates of insurance showing the insurance coverages, as well as providing the City with the required endorsements in a form and content approved by City, prior to performing any services under this Agreement.
The certificates of insurance and endorsements shall be attached hereto as Exhibit "C" and incorporated herein by this reference.
5.4. Non -limiting.. Nothing in this Section shall be construed as limiting in any way, the indemnification provision contained in this Agreement, or the extent to which Consultant may be 5 [Placeworks, Inc.]
Rev. 01/2024
held responsible for payments of damages to persons or property.
6.0. GENERAL PROVISIONS
6.1. Entire Agreement. This Agreement constitutes the entire agreement between the parties with respect to any matter referenced herein and supersedes any and all other prior writings and oral negotiations. This Agreement may be modified only in writing and signed by the parties in interest at the time of such modification. The terms of this Agreement shall prevail over any inconsistent provision in any other contract document appurtenant hereto, including exhibits to this Agreement.
6.2. Representatives. The City Administrator or his or her designee shall be the representative of City for purposes of this Agreement and may issue all consents, approvals, directives, and agreements on behalf of the City, called for by this Agreement, except as otherwise expressly provided in this Agreement.
Consultant shall designate a representative for purposes of this Agreement who shall be authorized to issue all consents, approvals, directives, and agreements on behalf of Consultant called for by this Agreement, except as otherwise expressly provided in this Agreement.
6.3. Proiect Managers. City shall designate a Project Manager to work directly with Consultant in the performance of this Agreement. It shall be the Consultant's responsibility to assure that the Project Manager is kept informed of the progress of the performance of the services and the Consultant shall refer any decision, which must be made by City, to the Project Manager. Unless otherwise specified herein, any approval of City required hereunder shall mean the approval of the Project Manager.
Consultant shall designate a Project Manager who shall represent it and be its agent in all consultations with City during the term of this Agreement and who shall not be changed by Consultant without the express written approval by the City. Consultant or its Project Manager shall attend and assist in all coordination meetings called by City.
6.4. Notices. Any notices, documents, correspondence, or other communications concerning this Agreement or the work hereunder may be provided by personal delivery, facsimile or if mailed, shall be addressed as set forth below and placed in a sealed envelope, postage prepaid, and deposited in the United States Postal Service. Such communication shall be deemed served or delivered: a) at the time of delivery if such communication is sent by personal delivery; b) at the time of transmission if such communication is sent by facsimile; and c) 72 hours after deposit in the U.S. Mail as reflected by the official U.S. postmark if such communication is sent through regular United States mail.
IF TO CONSULTANT:
PLACEWORKS, INC.
3 MacArthur Place, Suite 1100
Santa Ana, CA 92707
Attn: Karen Gulley,
Vice President and Managing Principal, Design
Tel: (714) 966-9220 ex.2347
6 IF TO CITY:
City of Placentia
401 E. Chapman Ave.
Placentia, CA 92870
[Placeworks, Inc.]
Rev. 01/2024
E-Mail: [email protected]
Attn: Joe Lambert
(714) 993-8124
[email protected]
6.5. Attorneys' Fees. In the event that litigation is brought by any party in connection with this Agreement, the prevailing party shall be entitled to recover from the opposing party all costs and expenses, including reasonable attorneys' fees, incurred by the prevailing party in the exercise of any of its rights or remedies hereunder or the enforcement of any of the terms, conditions, or provisions hereof.
6.6. Governing Law. This Agreement shall be governed by and construed under the laws of the State of California without giving effect to that body of laws pertaining to conflict of laws. In the event of any legal action to enforce or interpret this Agreement, the parties hereto agree that the sole and exclusive venue shall be a court of competent jurisdiction located in Orange County, California. Consultant agrees to submit to the personal jurisdiction of such court in the event of such action.
6.7. Assignment. Consultant shall not voluntarily or by operation of law assign, transfer, sublet, or encumber all or any part of Consultant's interest in this Agreement without City's prior written consent. Any attempted assignment, transfer, subletting, or encumbrance shall be void and shall constitute a breach of this Agreement and cause for termination of this Agreement. Regardless of City's consent, no subletting or assignment shall release Consultant of Consultant's obligation to perform all other obligations to be performed by Consultant hereunder for the term of this Agreement.
6.8. Indemnification and Hold Harmless. Consultant agrees to protect, defend, indemnify, and hold free and harmless the City, its officers, officials, agents, employees, and volunteers, at Consultant's sole expense, from and against any and all claims, liabilities, demands, actions, expenses, damages, suits or other legal proceedings brought against the City, its officers, officials, agents, employees, and volunteers arising out of or in any way connected with the performance of the Consultant, its employees, and/or authorized subcontractors' work undertaken pursuant to this Agreement including all acts or omissions, willful misconduct or negligent conduct, whether active or passive, on the part of the Consultant, its employees and/or subcontractors. The defense obligation provided for hereunder shall apply whenever any claim, action, complaint or suit asserts liability against the City, its officers, officials, agents, employees, and volunteers based upon the work performed by the Consultant, its employees, and/or authorized subcontractors under this Agreement, whether or not the Consultant, its employees, and/or authorized subcontractors are specifically named or otherwise asserted to be liable, and whether or not there is any evidence of fault or wrongdoing by the Consultant, its employees and/or its subcontractors. Notwithstanding the foregoing, the Consultant shall not be liable for the defense or indemnification of the City for claims, actions, complaints or suits arising out of the sole active negligence or willful misconduct of the City. This provision shall supersede and replace all other indemnity provisions contained either in the City's specifications or Consultant's Proposal, which shall be of no force and effect.
6.9. Independent Contractor. Consultant is and shall be acting at all times as an independent contractor and not as an employee of City. Consultant shall have no power to incur 7 [Placeworks, Inc.]
Rev. 01/2024
any debt, obligation, or liability on behalf of City or otherwise act on behalf of City as an agent.
Neither City nor any of its agents shall have control over the conduct of Consultant or any of Consultant's employees, except as set forth in this Agreement. Consultant shall not, at any time, or in any manner, represent that it or any of its or employees are in any manner agents or employees of City. Consultant shall secure, at its sole expense, and be responsible for any and all payment of Income Tax, Social Security, State Disability Insurance Compensation, Unemployment Compensation, and other payroll deductions for Consultant and its officers, agents, and employees, and all business licenses, if any are required, in connection with the services to be performed hereunder. Consultant shall indemnify and hold City harmless from any and all taxes, assessments, penalties, and interest asserted against City by reason of the independent contractor relationship created by this Agreement. Consultant further agrees to indemnify and hold City harmless from any failure of Consultant to comply with the applicable worker's compensation laws. City shall have the right to offset against the amount of any fees due to Consultant under this Agreement any amount due to City from Consultant as a result of Consultant's failure to promptly pay to City any reimbursement or indemnification arising under this paragraph.
6.10. PERS Eligibility Indemnification. In the event that Consultant or any employee, agent, or subcontractor of Consultant providing services under this Agreement claims or is determined by a court of competent jurisdiction or the California Public Employees Retirement System (PERS) to be eligible for enrollment in PERS as an employee of the City, Consultant shall indemnify, defend, and hold harmless City for the payment of any employee and/or employer contributions for PERS benefits on behalf of Consultant or its employees, agents, or subcontractors, as well as for the payment of any penalties and interest on such contributions, which would otherwise be the responsibility of City.
Notwithstanding any other agency, State, or Federal policy, rule, regulation, law, or ordinance to the contrary, Consultant and any of its employees, agents, and subcontractors providing service under this Agreement shall not qualify for or become entitled to, and hereby agree to waive any claims to, any compensation, benefit, or any incident of employment by City, including but not limited to eligibility to enroll in PERS as an employee of City and entitlement to any contribution to be paid by City for employer contribution and/or employee contributions for PERS benefits.
6.11. Cooperation. In the event any claim or action is brought against City relating to Consultant's performance or services rendered under this Agreement, Consultant shall render any reasonable assistance and cooperation which City might require.
6.12. Ownership of Documents. All findings, reports, documents, information, and data including, but not limited to, computer tapes or discs, preliminary notes, working documents, files, and tapes furnished or prepared by Consultant or any of its subcontractors in the course of performance of this Agreement, shall be and remain the sole property of City. Consultant agrees that any such documents or information shall not be made available to any individual or organization without the prior consent of City but shall be made available to the City within ten (10) days of request or within ten (10) days of termination. Any use of such documents for other projects not contemplated by this Agreement, and any use of incomplete documents, shall be at the sole risk of City and without liability or legal exposure to Consultant. City shall indemnify and hold harmless Consultant from all claims, damages, losses, and expenses, including attorneys' fees, arising out of or resulting from City's use of such documents for other projects not contemplated by this Agreement or use of incomplete documents furnished by Consultant. 8 [Placeworks, Inc.]
Rev. 01/2024
Consultant shall deliver to City any findings, reports, documents, information, data, preliminary notes and working documents, in any form, including but not limited to, computer tapes, discs, files audio tapes, or any other Project related items as requested by City or its authorized representative, at no additional cost to the City. Consultant or Consultant's agents shall execute such documents as may be necessary from time to time to confirm City's ownership of the copyright in such documents.
6.13. Public Records Act Disclosure. Consultant has been advised and is aware that this Agreement and all reports, documents, information, and data, including, but not limited to, computer tapes, discs, or files furnished or prepared by Consultant, or any of its subcontractors, pursuant to this Agreement and provided to City may be subject to public disclosure as required by the California Public Records Act (California Government Code Section 7920.000 et seq.). Exceptions to public disclosure may be those documents or information that qualify as trade secrets, as that term is defined in the California Government Code Section 7924.510, and of which Consultant informs City of such trade secret. The City will endeavor to maintain as confidential all information obtained by it that is designated as a trade secret. The City shall not, in any way, be liable or responsible for the disclosure of any trade secret including, without limitation, those records so marked if disclosure is deemed to be required by law or by order of the Court.
6.14. Conflict of Interest. Consultant and its officers, employees, associates, and subconsultants, if any, will comply with all conflict of interest statutes of the State of California applicable to Consultant's services under this agreement, including, but not limited to, the Political Reform Act (Government Code Sections 81000, et seq.) and Government Code Section 1090.
During the term of this Agreement, Consultant and its officers, employees, associates, and subconsultants shall not, without the prior written approval of the City Representative, perform work for another person or entity for whom Consultant is not currently performing work that would require Consultant or one of its officers, employees, associates, or subconsultants to abstain from a decision under this Agreement pursuant to a conflict of interest statute. Consultant's duties and services under this Agreement shall not include preparing or assisting the City with any portion of the City's preparation of a request for proposals, request for qualifications, or any other solicitation regarding a subsequent or additional contract with the City. The City shall at all times retain responsibility for public contracting, including with respect to any subsequent phase of this project.
Consultant's participation in the planning, discussions, or drawing of project plans or specifications shall be limited to conceptual, preliminary, or initial plans or specifications.
Consultant shall cooperate with the public entity to ensure that all bidders for a subsequent contract on any subsequent phase of this project, if any, have access to the same information, including all conceptual, preliminary, or initial plans or specifications prepared by Consultant pursuant to this Agreement.
6.15. Responsibility for Errors. Consultant shall be responsible for its work and results under this Agreement. Consultant, when requested, shall furnish clarification and/or explanation as may be required by the City's representative, regarding any services rendered under this Agreement at no additional cost to City. In the event that an error or omission attributable to Consultant occurs, then Consultant shall, at no cost to City, provide all necessary design drawings, estimates, and other Consultant professional services necessary to rectify and correct the matter to the sole satisfaction of City and to participate in any meeting required with regard to the correction.
6.16. Prohibited Employment. Consultant will not employ any regular employee of City 9 [Placeworks, Inc.]
Rev. 01/2024
while this Agreement is in effect.
6.17. Order of Precedence. In the event of an inconsistency in this Agreement and any of the attached Exhibits, the terms set forth in this Agreement shall prevail. If, and to the extent this Agreement incorporates by reference any provision of any document, such provision shall be deemed a part of this Agreement. Nevertheless, if there is any conflict among the terms and conditions of this Agreement and those of any such provision or provisions so incorporated by reference, the conflict shall be resolved by giving precedence in the following order, if applicable:
This Agreement, the City's Request for Proposals, the Consultant's Proposal.
6.18. Costs. Each party shall bear its own costs and fees incurred in the preparation and negotiation of this Agreement and in the performance of its obligations hereunder except as expressly provided herein.
6.19. No Third Party Beneficiary Rights. This Agreement is entered into for the sole benefit of City and Consultant and no other parties are intended to be direct or incidental beneficiaries of this Agreement and no third party shall have any right in, under or to this Agreement.
6.20. Headings. Paragraphs and subparagraph headings contained in this Agreement are included solely for convenience and are not intended to modify, explain or to be a full or accurate description of the content thereof and shall not in any way affect the meaning or interpretation of this Agreement.
6.21. Construction. The parties have participated jointly in the negotiation and drafting of this Agreement. In the event an ambiguity or question of intent or interpretation arises with respect to this Agreement, this Agreement shall be construed as if drafted jointly by the parties and in accordance with its fair meaning. There shall be no presumption or burden of proof favoring or disfavoring any party by virtue of the authorship of any of the provisions of this Agreement.
6.22. Amendments. Only a writing executed by the parties hereto or their respective successors and assigns may amend this Agreement.
6.23. Waiver. The delay or failure of either party at any time to require performance or compliance by the other of any of its obligations or agreements shall in no way be deemed a waiver of those rights to require such performance or compliance. No waiver of any provision of this Agreement shall be effective unless in writing and signed by a duly authorized representative of the party against whom enforcement of a waiver is sought. The waiver of any right or remedy in respect to any occurrence or event shall not be deemed a waiver of any right or remedy in respect to any other occurrence or event, nor shall any waiver constitute a continuing waiver.
6.24. Severabilitv. If any provision of this Agreement is determined by a court of competent jurisdiction to be unenforceable in any circumstance, such determination shall not affect the validity or enforceability of the remaining terms and provisions hereof or of the offending provision in any other circumstance. Notwithstanding the foregoing, if the value of this Agreement, based upon the substantial benefit of the bargain for any party, is materially impaired, which determination made by the presiding court or arbitrator of competent jurisdiction shall be binding, then both parties agree to substitute such provision(s) through good faith negotiations.
6.25. Counterparts. This Agreement may be executed in one or more counterparts, 10 [Placeworks, Inc.]
Rev. 01/2024
each of which shall be deemed an original. All counterparts shall be construed together and shall constitute one agreement.
6.26. Corporate Authority. The persons executing this Agreement on behalf of the parties hereto warrant that they are duly authorized to execute this Agreement on behalf of said parties and that by doing so the parties hereto are formally bound to the provisions of this Agreement.
IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by and through their respective authorized officers, as of the date first above written.
CITY OF PLACENTIA,
A municipal corporation
Mayor
ATTEST:
City Clerk and ex -officio Clerk
of the City of Placentia
CONSULTANT:
Signature
Name and Title
Social Security or Taxpayer ID Number
APPROVED AS TO FORM:
Christian L. Bettenhausen, City Attorney
APPROVED AS TO INSURANCE:
11 Date:
Date:
Date:
[Placeworks, Inc.]
Rev. 01/2024
Risk Manager
APPROVED AS TO CONTENT:
Joe Lambert, Project Manager
DEPARTMENTAL APPROVAL:
Date:
Date:
Date:
Joe Lambert, Director of Development Services
12 [Placeworks, Inc.]
Rev. 01/2024
EXHIBIT A
CONSULTANT'S PROPOSAL AND SCOPE OF WORK
13 [Placeworks, Inc.]
Rev. 01/2024
EXHIBIT B
INSURANCE REQUIREMENTS
14 [Placeworks, Inc.]
Rev. 01/2024
EXHIBIT C
CERTIFICATES OF INSURANCE AND ENDORSEMENTS
15 [Placeworks, Inc.]
Rev. 01/2024