-1- Professional Services Agreement
CITY OF PLEASANT HILL
PROFESSIONAL SERVICES AGREEMENT
1. PARTIES AND DATE.
This Agreement is made and entered into this _____ day of ________, 20___, by and between the City of Pleasant Hill, a municipal corporation, organized under the laws of the State of California, with its principal place of business at 100 Gregory Lane, Pleasant Hill, CA 94523 ("City") and RRM Design Group, a California Corporation, with its principal place of business at 3765 S. Higuera Street, Ste 102, San Luis Obispo, CA 93401 ("Consultant"). City and Consultant are sometimes individually referred to herein as "Party" and collectively as "Parties."
2. RECITALS.
2.1 Consultant.
Consultant desires to perform and assume responsibility for the provision of certain professional services required by the City on the terms and conditions set forth in this Agreement. Consultant represents that it is experienced in providing planning and building related services to public clients, is licensed in the State of California, and is familiar with the plans of City.
2.2 Project.
City desires to engage Consultant to render such professional services for the “Permit Ready Accessory Dwelling Unit” project ("Project") as set forth in this Agreement.
3. TERMS.
3.1 Scope of Services and Term.
3.1.1 General Scope of Services. Consultant promises and agrees to furnish to the City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the professional planning and building related consulting services necessary for the Project ("Services"). The Services are more particularly described in Exhibit "A" attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordance with, this Agreement, the exhibits attached hereto and incorporated herein by reference, and all applicable local, state and federal laws, rules and regulations. Additionally, Consultant shall comply with all Federal requirements applicable to the Services as set forth in Exhibit “A-I.”
3.1.2 Term. The term of this Agreement shall be from _____________ ____, 2024 to January 1, 2025, unless earlier terminated as provided herein. Consultant shall complete the Services within the term of this Agreement, and shall meet any other established schedules and deadlines. -2- Professional Services Agreement
3.2 Compensation.
3.2.1 Compensation. Consultant shall receive compensation, including authorized reimbursements, for all Services rendered under this Agreement at the rates set forth in Exhibit "C" attached hereto and incorporated herein by reference. The total compensation shall not exceed ninety four thousand, nine hundred fifty dollars ($94,950) without written approval of the City Council or City Manager, as applicable. Extra Work may be authorized, as described below, and if authorized, will be compensated at the rates and manner set forth in this Agreement.
3.2.2 Payment of Compensation. Consultant shall submit to City a monthly invoice which indicates work completed and hours of Services rendered by Consultant. The invoice shall describe the amount of Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the invoice. City shall, within 30 days of receiving such invoice, review the invoice and pay all non-disputed and approved charges. If the City disputes any of Consultant's fees, the City shall give written notice to Consultant within thirty (30) days of receipt of an invoice of any disputed fees set forth therein. Payment shall not constitute acceptance of any Services completed by Consultant. The making of final payment shall not constitute a waiver of any claims by the City for any reason whatsoever.
3.2.3 Reimbursement for Expenses. Consultant shall not be reimbursed for any expenses unless authorized in writing by City, or included in Exhibit "C" of this Agreement.
3.2.4 Extra Work. At any time during the term of this Agreement, City may request that Consultant perform Extra Work. As used herein, "Extra Work" means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement. Consultant shall not perform, nor be compensated for, Extra Work without written authorization from the City.
3.2.5 Rate Increases. In the event that this Agreement is renewed pursuant to Section 3.1.2, the rate set forth in Exhibit “C” may be adjusted each year at the time of renewal as set forth in Exhibit “C.”
3.3 Responsibilities of Consultant.
3.3.1 Independent Contractor; Control and Payment of Subordinates. The Services shall be performed by Consultant or under its supervision. Consultant will determine the means, methods and details of performing the Services subject to the requirements of this Agreement. City retains Consultant on an independent contractor basis and not as an employee. Consultant retains the right to perform similar or different services for others during the term of this Agreement. Any personnel performing the Services on behalf of Consultant shall also not be employees of City and shall at all times be under Consultant's exclusive direction and control. Neither City, nor any of its officials, officers, directors, employees or agents shall have control over the conduct of Consultant or any of Consultant's officers, employees, or agents, except as set forth in this Agreement. Consultant shall pay all wages, salaries, and other amounts due such personnel in connection with their performance of Services under this Agreement and as required by law. Consultant shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers' compensation insurance.
3.3.2 Schedule of Services. Consultant shall perform the Services expeditiously, within the term of this Agreement, and in accordance with the Schedule of Services set forth in Exhibit "B" attached hereto and incorporated herein by reference. Consultant represents that it has the professional and technical personnel required to perform the Services in conformance with such conditions. In order to facilitate Consultant's conformance with the Schedule, City shall respond to Consultant's submittals in a timely manner. Upon request of City, Consultant shall provide a more detailed schedule of anticipated -3- Professional Services Agreement
performance to meet the Schedule of Services.
3.3.3 Conformance to Applicable Requirements. All work prepared by Consultant shall be subject to the approval of City.
3.3.4 Substitution of Key Personnel. Consultant has represented to City that certain key personnel will perform and coordinate the Services under this Agreement. Should one or more of such personnel become unavailable, Consultant may substitute other personnel of at least equal competence upon written approval of City. In the event that City and Consultant cannot agree as to the substitution of key personnel, City shall be entitled to terminate this Agreement for cause. The key personnel for performance of this Agreement are as follows: Randy Russom, Principal and Project Manager; Scott Martin, Design Director; Jami Williams, Support Staff; Jessica Meadows, Support Staff; and Tim Carstairs, Subconsultant with Carstairs Energy.
3.3.5 City's Representative. The City hereby designates Haley Croffoot, Senior Planner, or his/her designee, to act as its representative in all matters pertaining to the administration and performance of this Agreement ("City's Representative"). City's Representative shall have the power to act on behalf of the City for review and approval of all products submitted by Consultant but not the authority to enlarge the Scope of Services or change the total compensation due to Consultant under this Agreement.
The City Manager shall be authorized to act on City's behalf and to execute all necessary documents which enlarge the Scope of Services or change the Consultant's total compensation subject to the provisions contained in this Agreement. Consultant shall not accept direction or orders from any person other than the City Manager, City's Representative or his/her designee.
3.3.6 Consultant's Representative. Consultant hereby designates Randy Russom, Principal and Project Manager, or his/her designee, to act as its representative for the performance of this Agreement ("Consultant's Representative"). Consultant's Representative shall have full authority to represent and act on behalf of the Consultant for all purposes under this Agreement. The Consultant's Representative shall supervise and direct the Services, using his/her best skill and attention, and shall be responsible for all means, methods, techniques, sequences, and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.
3.3.7 Coordination of Services. Consultant agrees to work closely with City staff in the performance of Services and shall be available to City's staff, consultants and other staff at all reasonable times.
3.3.8 Standard of Care; Performance of Employees. Consultant shall perform all Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals in the same discipline in the State of California. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services.
Consultant represents that all employees and subconsultants shall have sufficient skill and experience to perform the Services assigned to them. Finally, Consultant represents that it, its employees and subconsultants have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services, and that such licenses and approvals shall be maintained throughout the term of this Agreement. Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant's failure to comply with the standard of care provided for herein. Any employee of the Consultant or its subconsultants who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed from the -4- Professional Services Agreement
Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.
3.3.9 Period of Performance.
3.3.9.1 Consultant shall perform and complete all Services under this Agreement within the term set forth in Section 3.1.2 above (“Performance Time”). Consultant shall also perform the Services in strict accordance with any completion schedule or Project milestones described in Exhibits “A” or “B” attached hereto, or which may be separately agreed upon in writing by the City and Consultant (“Performance Milestones”). Consultant agrees that if the Services are not completed within the aforementioned Performance Time and/or pursuant to any such Project Milestones developed pursuant to provisions of this Agreement, it is understood, acknowledged and agreed that the City will suffer damage.
3.3.9.2 Neither City nor Consultant shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the nonperforming Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Consultant and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the services and Agreement.
3.3.9.3 Should a Force Majeure Event occur, the non-performing Party shall, within a reasonable time of being prevented from performing, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events and/or delays, regardless of the Party responsible for the delay, shall not entitle Consultant to any additional compensation. Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement.
3.3.10 Laws and Regulations; Employee/Labor Certification. Consultant shall keep itself fully informed of and in compliance with all local, state and federal laws, rules and regulations in any manner affecting the performance of the Project or the Services, including all Cal/OSHA requirements, and shall give all notices required by law. Consultant shall be liable for all violations of such laws and regulations in connection with Services. If Consultant performs any work knowing it to be contrary to such laws, rules and regulations, Consultant shall be solely responsible for all costs arising therefrom. Consultant shall defend, indemnify and hold City, its officials, directors, officers, employees, agents, and volunteers free and harmless, pursuant to the indemnification provisions of this Agreement, from any claim or liability arising out of any failure or alleged failure to comply with such laws, rules or regulations.
3.3.10.1 Employment Eligibility; Consultant. Consultant certifies that it fully complies with all requirements and restrictions of state and federal law respecting the employment of undocumented aliens, including, but not limited to, the Immigration Reform and Control Act of 1986, as may be amended from time to time and shall require all subconsultants and sub-subconsultants to comply with the same. Consultant certifies that it has not committed a violation of any such law within the five (5) -5- Professional Services Agreement
years immediately preceding the date of execution of this Agreement, and shall not violate any such law at any time during the term of the Agreement.
3.3.10.2 Employment Eligibility; Failure to Comply. Each person executing this Agreement on behalf of Consultant verifies that they are a duly authorized officer of Consultant, and understands that any of the following shall be grounds for the City to terminate the Agreement for cause:
(1) failure of Consultant or its subcontractors, consultants, sub-subcontractors or subconsultants to meet any of the requirements provided for in Sections 3.3.10.1 or 3.3.10.2; (2) any misrepresentation or material omission concerning compliance with such requirements (including in those verifications provided to the Consultant under Section 3.3.10.2); or (3) failure to immediately remove from the Project any person found not to be in compliance with such requirements.
3.3.10.3 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subconsultant, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. Such nondiscrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination. Consultant shall also comply with all relevant provisions of City's Minority Business Enterprise program, Affirmative Action Plan or other related programs or guidelines currently in effect or hereinafter enacted.
3.3.10.4 Air Quality. To the extent applicable, Consultant must fully comply with all applicable laws, rules and regulations in furnishing or using equipment and/or providing services, including, but not limited to, emissions limits and permitting requirements imposed by the South Coast Air Quality Management District (SCAQMD) and/or California Air Resources Board (CARB). Consultant shall indemnify City against any fines or penalties imposed by SCAQMD, CARB, or any other governmental or regulatory agency for violations of applicable laws, rules and/or regulations by Consultant, its subconsultants, or others for whom Consultant is responsible under its indemnity obligations provided for in this Agreement.
3.3.10.5 Water Quality Management and Compliance. Consultant shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Services including, without limitation, all applicable provisions of the City’s ordinances regulating water quality and storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251, et seq.); the California PorterCologne Water Quality Control Act (Water Code § 13000 et seq.); and any and all regulations, policies, or permits issued pursuant to any such authority. Consultant must additionally comply with the lawful requirements of the City, and any other municipality, drainage district, or other local agency with jurisdiction over the location where the Services are to be conducted, regulating water quality and storm water discharges. City may seek damages from Consultant for delay in completing the Services caused by Consultant’s failure to comply with the laws, regulations and policies described in this Section, or any other relevant water quality law, regulation, or policy.
3.3.10.6 Safety. Consultant shall execute and maintain its work so as to avoid injury or damage to any person or property. In carrying out its Services, the Consultant shall at all times be in compliance with all applicable local, state and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of employees appropriate to the nature of the work and the conditions under which the work is to be performed.
3.3.11 Insurance.
-6- Professional Services Agreement
3.3.11.1 Time for Compliance. Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurance required under this section. Failure to provide and maintain all required insurance shall be grounds for the City to terminate this Agreement for cause.
3.3.11.2 Types of Insurance Required. As a condition precedent to the effectiveness of this Agreement for work to be performed hereunder, and without limiting the indemnity provisions of the Agreement, the Consultant, in partial performance of its obligations under such Agreement, shall procure and maintain in full force and effect during the term of the Agreement the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Consultant agrees to amend, supplement or endorse the policies to do so. (A) Commercial General Liability: Commercial General Liability Insurance which affords coverage at least as broad as Insurance Services Office "occurrence" form CG 00 01, or the exact equivalent, with limits of not less than $1,000,000 per occurrence and no less than $2,000,000 in the general aggregate. Defense costs shall be paid in addition to the limits. The policy shall contain no endorsements or provisions (1) limiting coverage for contractual liability; (2) excluding coverage for claims or suits by one insured against another (cross-liability); (3) products/completed operations liability; or (4) containing any other exclusion(s) contrary to the terms or purposes of this Agreement. (B) Automobile Liability Insurance: Automobile Liability Insurance with coverage at least as broad as Insurance Services Office Form CA 00 01 covering "Any Auto" (Symbol 1), or the exact equivalent, covering bodily injury and property damage for all activities with limits of not less than $1,000,000 combined limit for each occurrence. (C) Workers' Compensation: Workers' Compensation Insurance, as required by the State of California and Employer's Liability Insurance with a limit of not less than $1,000,000 per accident for bodily injury and disease.
(D) Professional Liability (Errors & Omissions): Professional Liability insurance or Errors & Omissions insurance appropriate to Consultant’s profession with limits of not less than $1,000,000. Covered professional services shall specifically include all work to be performed under the Agreement and delete any exclusions that may potentially affect the work to be performed (for example, any exclusions relating to lead, asbestos, pollution, testing, underground storage tanks, laboratory analysis, soil work, etc.). If coverage is written on a claims-made basis, the retroactive date shall precede the effective date of the initial Agreement and continuous coverage will be maintained or an extended reporting period will be exercised for a period of at least five (5) years from termination or expiration of this Agreement.
3.3.11.3 Insurance Endorsements. Required insurance policies shall contain the following provisions, or Consultant shall provide endorsements on forms approved by the City to add the following provisions to the insurance policies:
(A) Commercial General Liability: (1) Additional Insured: The City, its officials, officers, employees, agents, and volunteers shall be additional insureds with regard to liability and defense of suits or claims arising out of the performance of the Agreement. Additional Insured Endorsements shall not (1) be restricted to "ongoing operations"; (2) exclude "contractual liability"; (3) restrict coverage to "sole" liability of Consultant; or (4) contain any other exclusions contrary to the terms -7- Professional Services Agreement
or purposes of this Agreement. For all policies of Commercial General Liability insurance, Consultant shall provide endorsements in the form of ISO CG 20 10 10 01 and 20 37 10 01 (or endorsements providing the exact same coverage) to effectuate this requirement. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (B) Automobile Liability. (1) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (C) Professional Liability (Errors & Omissions): (1) Cancellation:
Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) Contractual Liability Exclusion Deleted: This insurance shall include contractual liability applicable to this Agreement. The policy must “pay on behalf of” the insured and include a provision establishing the insurer’s duty to defend.
(D) Workers' Compensation: (1) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) Waiver of Subrogation: A waiver of subrogation stating that the insurer waives all rights of subrogation against the City, its officials, officers, employees, agents, and volunteers.
3.3.11.4 Primary and Non-Contributing Insurance. All policies of insurance shall be primary and any other insurance, deductible, or self-insurance maintained by the City, its officials, officers, employees, agents, or volunteers shall not contribute with this primary insurance. Policies shall contain or be endorsed to contain such provisions, except with respect to professional liability.
3.3.11.5 Waiver of Subrogation. All required insurance coverages, except for the professional liability coverage, shall contain or be endorsed to waiver of subrogation in favor of the City, its officials, officers, employees, agents, and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these specifications to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants.
3.3.11.6 Deductibles and Self-Insured Retentions. Any deductible or selfinsured retention must be approved in writing by the City and shall protect the City, its officials, officers, employees, agents, and volunteers in the same manner and to the same extent as they would have been protected had the policy or policies not contained a deductible or self-insured retention.
3.3.11.7 Evidence of Insurance. The Consultant, concurrently with the execution of the Agreement, and as a condition precedent to the effectiveness thereof, shall deliver either certified copies of the required policies, or original certificates on forms approved by the City, together with all endorsements affecting each policy. Required insurance policies shall not be in compliance if they include any limiting provision or endorsement that has not been submitted to the City for approval. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf. At least fifteen (15 days) prior to the expiration of any such policy, evidence of insurance showing that such insurance coverage has been renewed or extended shall be filed with the City. If such coverage is cancelled or reduced and not replaced immediately so as to avoid a lapse in the required coverage, Consultant shall, within ten (10) days after receipt of written notice of such -8- Professional Services Agreement
cancellation or reduction of coverage, file with the City evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies.
3.3.11.8 Acceptability of Insurers. Each such policy shall be from a company or companies with a current A.M. Best's rating of no less than A:VII and authorized to transact business of insurance in the State of California, or otherwise allowed to place insurance through surplus line brokers under applicable provisions of the California Insurance Code or any federal law.
3.3.11.9 Enforcement of Agreement Provisions (non estoppel). Consultant acknowledges and agrees that actual or alleged failure on the part of the City to inform Consultant of noncompliance with any requirement imposes no additional obligation on the City nor does it waive any rights hereunder.
3.3.11.10 Requirements Not Limiting. Requirement of specific coverage or minimum limits contained in this Section are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance.
3.3.11.11 Additional Insurance Provisions
(A) The foregoing requirements as to the types and limits of insurance coverage to be maintained by Consultant, and any approval of said insurance by the City, is not intended to and shall not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Consultant pursuant to this Agreement, including but not limited to, the provisions concerning indemnification.
(B) If at any time during the life of the Agreement, any policy of insurance required under this Agreement does not comply with these specifications or is canceled and not replaced, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Consultant or City will withhold amounts sufficient to pay premium from Consultant payments. In the alternative, City may cancel this Agreement. (C) The City may require the Consultant to provide complete copies of all insurance policies in effect for the duration of the Project. (D) Neither the City nor any of its officials, officers, employees, agents or volunteers shall be personally responsible for any liability arising under or by virtue of this Agreement.
(E) The limits set forth herein shall apply separately to each insured against whom claims are made or suits are brought, except with respect to the limits of liability. Further the limits set forth herein shall not be construed to relieve the Consultant from liability in excess of such coverage, nor shall it limit the Consultant’s indemnification obligations to the City and shall not preclude the City from taking such other actions available to the City under other provisions of the Agreement or law.
(F) Consultant shall report to the City, in addition to Consultant’s insurer, any and all insurance claims submitted by Consultant in connection with the Services under this Agreement.
-9- Professional Services Agreement
3.3.11.12 Insurance for Subconsultants. Consultant shall include all subconsultants engaged in any work for Consultant relating to this Agreement as additional insureds under the Consultant's policies, or the Consultant shall be responsible for causing subconsultants to purchase the appropriate insurance in compliance with the terms of these Insurance Requirements, including adding the City, its officials, officers, employees, agents, and volunteers as additional insureds to the subconsultant's policies. All policies of Commercial General Liability insurance provided by Consultant’s subconsultants performing work relating to this Agreement shall be endorsed to name the City, its officials, officers, employees, agents and volunteers as additional insureds using endorsement form ISO CG 20 38 04 13 or an endorsement providing equivalent coverage. Consultant shall not allow any subconsultant to commence work on any subcontract relating to this Agreement until it has received satisfactory evidence of subconsultant’s compliance with all insurance requirements under this Agreement, to the extent applicable.
The Consultant shall provide satisfactory evidence of compliance with this section upon request of the City.
3.4 Labor Code Requirements.
3.4.1 Prevailing Wages. Consultant is aware of the requirements of California Labor Code Section 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., ("Prevailing Wage Laws"), which require the payment of prevailing wage rates and the performance of other requirements on "public works" and "maintenance" projects. If the Services are being performed as part of an applicable "public works" or "maintenance" project, as defined by the Prevailing Wage Laws, and if the total compensation is $1,000 or more, Consultant agrees to fully comply with such Prevailing Wage Laws. City shall provide Consultant with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Consultant shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services available to interested parties upon request, and shall post copies at the Consultant's principal place of business and at the project site. It is the intent of the parties to effectuate the requirements of sections 1771, 1774, 1775, 1776, 1777.5, 1813, and 1815 of the Labor Code within this Agreement, and Consultant shall therefore comply with such Labor Code sections to the fullest extent required by law. Consultant shall defend, indemnify and hold the City, its officials, officers, employees, agents, and volunteers free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws.
3.4.2 Registration/DIR Compliance. If the Services are being performed on a public works project of over $25,000 when the project is for construction, alteration, demolition, installation, or repair work, or a public works project of over $15,000 when the project is for maintenance work, in addition to the foregoing, then pursuant to Labor Code sections 1725.5 and 1771.1, the Consultant and all subconsultants must be registered with the Department of Industrial Relations (“DIR”). Consultant shall maintain registration for the duration of the Project and require the same of any subconsultants.
3.4.3 Compliance Monitoring. This Project may also be subject to compliance monitoring and enforcement by the DIR. It shall be Consultant’s sole responsibility to comply with all applicable registration and labor compliance requirements, including the submission of payroll records directly to the DIR. Any stop orders issued by the DIR against Consultant or any subconsultant that affect Consultant’s performance of services, including any delay, shall be Consultant’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Consultant caused delay and shall not be compensable by the City. Consultant shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the DIR against Consultant or any subconsultant.
-10- Professional Services Agreement
3.4.4 Labor Certification. By its signature hereunder, Consultant certifies that it is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker's Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services.
3.5 Accounting Records.
3.5.1 Maintenance and Inspection. Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to this Agreement. Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement.
3.6 General Provisions.
3.6.1 Termination of Agreement.
3.6.1.1 Grounds for Termination. City may, by written notice to Consultant, terminate the whole or any part of this Agreement at any time and without cause by giving written notice to Consultant of such termination, and specifying the effective date thereof, at least seven (7) days before the effective date of such termination. Upon termination, Consultant shall be compensated only for those Services which have been adequately rendered to City, and Consultant shall be entitled to no further compensation. Consultant may not terminate this Agreement except for cause. The rights and remedies of the City provided in this section shall not be exclusive and are in addition to any other rights and remedies provided by law, equity or under this Agreement.
3.6.1.2 Effect of Termination. If this Agreement is terminated as provided herein, City may require Consultant to provide all finished or unfinished Documents and Data and other information of any kind prepared by Consultant in connection with the performance of Services under this Agreement. Consultant shall be required to provide such document and other information within fifteen (15) days of the request.
3.6.1.3 Additional Services. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated.
3.6.2 Delivery of Notices. All notices permitted or required under this Agreement shall be given to the respective parties at the following address, or at such other address as the respective parties may provide in writing for this purpose:
Consultant: RRM Design Group
3765 S. Higuera Street, Ste. 102
San Luis Obispo, CA 93401
ATTN: Randy Russom, Principal
City: City of Pleasant Hill
100 Gregory Lane
-11- Professional Services Agreement
Pleasant Hill, CA 94523
ATTN: Haley Croffoot, Senior Planner
Such notice shall be deemed made when personally delivered or when mailed, forty-eight (48) hours after deposit in the U.S. Mail, first class postage prepaid and addressed to the party at its applicable address.
Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.
3.6.3 Ownership of Materials and Confidentiality.
3.6.3.1 Documents & Data; Licensing of Intellectual Property. This Agreement creates a non-exclusive and perpetual license for City to copy, use, modify, reuse, or sublicense any and all copyrights, designs, and other intellectual property embodied in plans, specifications, studies, drawings, estimates, and other documents or works of authorship fixed in any tangible medium of expression, including but not limited to, physical drawings or data magnetically or otherwise recorded on computer diskettes, which are prepared or caused to be prepared by Consultant under this Agreement ("Documents & Data"). All Documents & Data shall be and remain the property of City, and shall not be used in whole or in substantial part by Consultant on other projects without the City’s express written permission. Within thirty (30) days following the completion, suspension, abandonment or termination of this Agreement, Consultant shall provide to City reproducible copies of all Documents & Data, in a form and amount required by City. City reserves the right to select the method of document reproduction and to establish where the reproduction will be accomplished. The reproduction expense shall be borne by City at the actual cost of duplication. In the event of a dispute regarding the amount of compensation to which the Consultant is entitled under the termination provisions of this Agreement, Consultant shall provide all Documents & Data to City upon payment of the undisputed amount. Consultant shall have no right to retain or fail to provide to City any such documents pending resolution of the dispute. In addition, Consultant shall retain copies of all Documents & Data on file for a minimum of fifteen (15) years following completion of the Project, and shall make copies available to City upon the payment of actual reasonable duplication costs. Before destroying the Documents & Data following this retention period, Consultant shall make a reasonable effort to notify City and provide City with the opportunity to obtain the documents.
3.6.3.2 Subconsultants. Consultant shall require all subconsultants to agree in writing that City is granted a non-exclusive and perpetual license for any Documents & Data the subconsultant prepares under this Agreement. Consultant represents and warrants that Consultant has the legal right to license any and all Documents & Data. Consultant makes no such representation and warranty in regard to Documents & Data which were prepared by design professionals other than Consultant or its subconsultants, or those provided to Consultant by the City.
3.6.3.3 Right to Use. City shall not be limited in any way in its use or reuse of the Documents and Data or any part of them at any time for purposes of this Project or another project, provided that any such use not within the purposes intended by this Agreement or on a project other than this Project without employing the services of Consultant shall be at City’s sole risk. If City uses or reuses the Documents & Data on any project other than this Project, it shall remove the Consultant’s seal from the Documents & Data and indemnify and hold harmless Consultant and its officers, directors, agents and employees from claims arising out of the negligent use or re-use of the Documents & Data on such other project. Consultant shall be responsible and liable for its Documents & Data, pursuant to the terms of this Agreement, only with respect to the condition of the Documents & Data at the time they are provided to the City upon completion, suspension, abandonment or termination. Consultant shall not be responsible or -12- Professional Services Agreement
liable for any revisions to the Documents & Data made by any party other than Consultant, a party for whom the Consultant is legally responsible or liable, or anyone approved by the Consultant.
3.6.3.4 Indemnification. Consultant shall defend, indemnify and hold the City, its directors, officials, officers, employees, and volunteers free and harmless, pursuant to the indemnification provisions of this Agreement, for any alleged infringement of any patent, copyright, trade secret, trade name, trademark, or any other proprietary right of any person or entity in consequence of the use on the Project by City of the Documents & Data, including any method, process, product, or concept specified or depicted.
3.6.3.5 Confidentiality. All ideas, memoranda, specifications, plans, procedures, drawings, descriptions, computer program data, input record data, written information, and other Documents & Data either created by or provided to Consultant in connection with the performance of this Agreement shall be held confidential by Consultant. Such materials shall not, without the prior written consent of City, be used by Consultant for any purposes other than the performance of the Services.
Nor shall such materials be disclosed to any person or entity not connected with the performance of the Services or the Project. Nothing furnished to Consultant which is otherwise known to Consultant or is generally known, or has become known, to the related industry shall be deemed confidential. Consultant shall not use City's name or insignia, photographs of the Project, or any publicity pertaining to the Services or the Project in any magazine, trade paper, newspaper, television or radio production or other similar medium without the prior written consent of City.
3.6.3.6 Confidential Information. The City shall refrain from releasing Consultant’s proprietary information ("Proprietary Information") unless the City's legal counsel determines that the release of the Proprietary Information is required by the California Public Records Act or other applicable state or federal law, or order of a court of competent jurisdiction, in which case the City shall notify Consultant of its intention to release Proprietary Information. Consultant shall have five (5) working days after receipt of the release notice to give City written notice of Consultant's objection to the City's release of Proprietary Information. Consultant shall indemnify, defend and hold harmless the City, and its officers, directors, employees, and agents from and against all liability, loss, cost or expense (including attorney’s fees) arising out of a legal action brought to compel the release of Proprietary Information. City shall not release the Proprietary Information after receipt of the objection notice unless either: (1) Consultant fails to fully indemnify, defend (with City's choice of legal counsel), and hold City harmless from any legal action brought to compel such release; and/or (2) a final and non-appealable order by a court of competent jurisdiction requires that City release such information.
3.6.4 Cooperation; Further Acts. The Parties shall fully cooperate with one another, and shall take any additional acts or sign any additional documents as may be necessary, appropriate or convenient to attain the purposes of this Agreement.
3.6.5 Indemnification.
3.6.5.1 To the fullest extent permitted by law, Consultant shall defend (with counsel of City’s choosing), indemnify and hold the City, its officials, officers, employees, volunteers, and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Consultant, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Consultant’s Services, the Project or this Agreement, including without limitation the payment of all damages, expert witness fees and attorney’s fees and other related costs and expenses except -13- Professional Services Agreement
such loss or damage caused by the sole negligence or willful misconduct of the City. Consultant's obligation to indemnify shall survive expiration or termination of this Agreement and shall not be restricted to insurance proceeds, if any, received by Consultant, the City, its officials, officers, employees, agents, or volunteers.
3.6.5.2 If Consultant’s obligation to defend, indemnify, and/or hold harmless arises out of Consultant’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Consultant’s indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Consultant, and, upon Consultant obtaining a final adjudication by a court of competent jurisdiction, Consultant’s liability for such claim, including the cost to defend, shall not exceed the Consultant’s proportionate percentage of fault.
3.6.6 Entire Agreement. This Agreement contains the entire Agreement of the parties with respect to the subject matter hereof, and supersedes all prior negotiations, understandings or agreements. This Agreement may only be modified by a writing signed by both parties.
3.6.7 Governing Law; Government Code Claim Compliance. This Agreement shall be governed by the laws of the State of California. Venue shall be in Contra Costa County. In addition to any and all contract requirements pertaining to notices of and requests for compensation or payment for extra work, disputed work, claims and/or changed conditions, Consultant must comply with the claim procedures set forth in Government Code sections 900 et seq. prior to filing any lawsuit against the City. Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to extra work, disputed work, claims, and/or changed conditions have been followed by Consultant. If no such Government Code claim is submitted, or if any prerequisite contractual requirements are not otherwise satisfied as specified herein, Consultant shall be barred from bringing and maintaining a valid lawsuit against the City.
3.6.8 Time of Essence. Time is of the essence for each and every provision of this Agreement.
3.6.9 City's Right to Employ Other Consultants. City reserves right to employ other consultants in connection with this Project.
3.6.10 Successors and Assigns. This Agreement shall be binding on the successors and assigns of the parties.
3.6.11 Assignment or Transfer. Consultant shall not assign, hypothecate, or transfer, either directly or by operation of law, this Agreement or any interest herein without the prior written consent of the City. Any attempt to do so shall be null and void, and any assignees, hypothecates or transferees shall acquire no right or interest by reason of such attempted assignment, hypothecation or transfer.
3.6.12 Construction; References; Captions. Since the Parties or their agents have participated fully in the preparation of this Agreement, the language of this Agreement shall be construed simply, according to its fair meaning, and not strictly for or against any Party. Any term referencing time, days or period for performance shall be deemed calendar days and not work days. All references to Consultant include all personnel, employees, agents, and subconsultants of Consultant, except as otherwise specified in this Agreement. All references to City include its elected officials, officers, employees, agents, and volunteers except as otherwise specified in this Agreement. The captions of the various articles and paragraphs are for convenience and ease of reference only, and do not define, limit, augment, or describe -14- Professional Services Agreement
the scope, content, or intent of this Agreement.
3.6.13 Amendment; Modification. No supplement, modification, or amendment of this Agreement shall be binding unless executed in writing and signed by both Parties.
3.6.14 Waiver. No waiver of any default shall constitute a waiver of any other default or breach, whether of the same or other covenant or condition. No waiver, benefit, privilege, or service voluntarily given or performed by a Party shall give the other Party any contractual rights by custom, estoppel, or otherwise.
3.6.15 No Third-Party Beneficiaries. There are no intended third party beneficiaries of any right or obligation assumed by the Parties.
3.6.16 Invalidity; Severability. If any portion of this Agreement is declared invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect.
3.6.17 Prohibited Interests. Consultant maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Consultant, to solicit or secure this Agreement. Further, Consultant warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability. For the term of this Agreement, no member, officer or employee of City, during the term of his or her service with City, shall have any direct interest in this Agreement, or obtain any present or anticipated material benefit arising therefrom.
3.6.18 Authority to Enter Agreement. Consultant has all requisite power and authority to conduct its business and to execute, deliver, and perform the Agreement. Each Party warrants that the individuals who have signed this Agreement have the legal power, right, and authority to make this Agreement and bind each respective Party.
3.6.19 Counterparts. This Agreement may be signed in counterparts, each of which shall constitute an original.
3.6.20 Survival. All rights and obligations hereunder that by their nature are to continue after any expiration or termination of this Agreement, including, but not limited to, the indemnification obligations, shall survive any such expiration or termination.
3.7 Subcontracting.
3.7.1 Prior Approval Required. Consultant shall not subcontract any portion of the work required by this Agreement, except as expressly stated herein, without prior written approval of City.
Subcontracts, if any, shall contain a provision making them subject to all provisions stipulated in this Agreement.
3.8 Federal Requirements. Coronavirus State and Local Fiscal Recovery Funds (“SLFRF”) will be used to fund all or a portion of this Agreement. The Consultant shall comply with all federal -15- Professional Services Agreement
requirements including, but not limited to, the following:
• Sections 602 and 603 of the Social Security Act as added by Section 9901 of the American Rescue Plan Act of 2021, U.S. Department of the Treasury Coronavirus State and Local Fiscal Recovery Fund Award Terms and Conditions, Treasury’s Final Rule codified at 31 CFR Part 35, and SLFRF reporting requirements, as applicable (collectively, the “SLFRF Compliance Requirements”). The SLFRF Compliance Requirements are expressly incorporated herein by reference.
• 2 C.F.R. Part 200 – Uniform Administrative Requirements, Cost Principles, and Audit Requirements for Federal Awards, other than such provisions as the Treasury may determine are inapplicable to the SLFRF program and subject to such exceptions as may be otherwise provided by the U.S. Department of the Treasury.
• Federal Contract Provisions attached hereto as Exhibit “A-1” and incorporated herein by reference.
Subcontracts, if any, shall contain a provision making them subject to all of the provisions stipulated in the Agreement, including but not limited to, SLFRF Compliance Requirements, 2 C.F.R. Part 200, and the Federal Contract Provisions. With respect to any conflict between such federal requirements and the terms herein and/or the provisions of state law and except as otherwise required under federal law or regulation, the more stringent requirement shall control.
[SIGNATURES ON NEXT PAGE]
Exhibit “A”-1 Professional Services Agreement
EXHIBIT "A"
SCOPE OF SERVICES
City of Pleasant Hill | Proposal FOR Permit-Ready Accessory Dwelling Unit Program 27
SCOPE OF SERVICES
ESTABLISH A STRONG FOUNDATION
In this project’s initial phase, the team will engage in a due diligence process to inform the team and key City staff on the primary issues to be addressed and to gather and review relevant data and background information.
TASK A.1: INITIATION MEETING
Following the review of existing data, the project team will meet with City staff to establish a mutual understanding of the key issues and goals, further define the scope and unit configuration, review and confirm the project schedule, layout of significant project milestones, meeting times, deliverable targets, and review pertinent data.
DELIVERABLES:
• One (1) meeting with City staff (virtual)
• One (1) meeting minutes
TASK A.2: DATA GATHERING AND DOCUMENT RESEARCH
As a first step in the process, the team will collect and review all data relevant from design guidelines, the general plan, the development code, specific plans, the local jurisdiction’s unique requirements, and other planning efforts that have a bearing on the communities. RRM will work with staff to compile a preliminary survey of existing City lots to identify the typical prevalent sizes and configurations. This informal review of lot stock helps guide design decisions to apply to as many locations as possible. Finally, RRM will prepare a program memo to document the project goals and alternatives the City wishes to achieve with the final designs.
DELIVERABLES:
• ADU due diligence memo
• One (1) meeting with City staff
ADU DESIGN
The baseline generic prototypes, which could be utilized as ADUs or standalone single-family dwellings designed to fit on generic flat lots, include the following:
• One (1) approximately 400-500 sf: Detached studio ADU in compliance with California Residential Code, not exceeding 16’ in height and designed to conform to a typical flat lot. • One (1) approximately 500 - 700 sf: Detached one-bedroom ADU in compliance with California Residential Code, not exceeding 16’ in height and designed to conform to a typical flat lot. • One (1) approximately 700 - 800 sf: Detached two-bedroom ADU in compliance with California Residential code, not exceeding 16’ in height and designed to conform to a typical flat lot Work Plan | SECTION 4
28 Each plan type will be designed to adapt to and include a total of three alternate exterior style treatments to conform to the City’s identified architectural vernacular.
Each of the three base plans may have design options, including ADA adaptable and fully accessible options, storage options, additional bedroom or flex space options, and multiple entry locations to allow personalization and site flexibility. This approach allows for the base plans to serve as many times as the number of designs.
TASK A.3: PRELIMINARY (30%) ADU DESIGN
RRM recognizes that residential design can be one of the purest manifestations of community character, and many people are passionate about homes. Therefore, RRM encourages a collaborative approach to working with staff to deliver designs that respond to the community’s unique character. Following the initial staff input in the tasks above, RRM will design a series of preliminary site plans/floor plans and elevations for the unit prototypes. We will review the designs with staff for comment and approval at approximately the 30% completion stage. The designs will include typical front elevation style options. Plans will be based on generic sites as directed by staff.
DELIVERABLES:
• PDF format submittal
• One (1) meeting with the City staff; a preliminary plan, massing, and elevation review meeting (virtual) • Preliminary site/floor plans for three (3) unit prototypes • Preliminary style options for front elevation of two (2) options per plan for a total of twelve (6) front elevations
MEETING:
• One (1) preliminary design (30% set) review meeting prior to the development of the final schematic design package for review and approval to proceed
TASK A.4: SCHEMATIC (65%) ADU DESIGN
Based on staff feedback on the preliminary design, RRM will refine the schematic design to an approximately 65% completion level for review by staff and any public outreach efforts. The submittal will be architecturespecific and for a non-specific generic site; no civil engineering or landscape architecture will be provided for review. At the end of this phase, all design work will be complete, and this is the opportunity for staff to share plans with stakeholders or policymakers for final revisions prior to permit plan preparation.
DELIVERABLES:
• PDF format 65% plan set
• Floor plans for three (3) ADU prototypes with design options • Sections for three (3) ADU prototypes
• Elevations for three (3) ADU prototypes; four (4) sides for each unit • Two (2) additional style options of the front elevations of each of the three (3) ADU base unit prototypes;
• Digital color and material boards; one (1) for each elevation style as printed images • Nine (9) 3D color-rendered front views suitable for publication SECTION 4 | Work Plan
City of Pleasant Hill | Proposal FOR Permit-Ready Accessory Dwelling Unit Program 29 MEETING:
• One (1) staff review meetings
TASK A.5: PUBLIC MEETINGS
RRM will attend one (1) in person public hearing to represent the project and support staff at the hearing.
We have provided an optional task for a second hearing if needed. RRM will provide graphics and support to staff-initiated public meetings. These meetings will be attended in person.
DELIVERABLES:
• Pre-planning commission staff meeting(s)
• Schematic design presentation package
MEETING:
• Attendance at one public hearing
• Optional attendance for a second public hearing.
ADU CONSTRUCTION DOCUMENTS
TASK A.6: DOCUMENT PREPARATION AND PLAN REVIEW
Our experience providing simple, cost-effective designs and plans complying with California Residential Code conventional construction requirements provides a strong base for further modification. A fully constructionready plan of conditions meets code requirements. All unit elevations are customizable to allow for variations in exterior materials and door and window fenestration to express individual owners’ tastes and community character. This will be achieved by stating the requirements of each exterior wall's minimum shear wall panel. Most interior walls will not be used for bearing, allowing further flexibility for the end user.
For construction cost, speed, and simplicity, designs are anticipated to utilize truss roof framing, but a stick frame option has been provided in the budget.
Our goal would be to express the design intent with a structural system that considers the most material and cost-efficient approach to provide a more implementable, affordable housing solution. This detailed review is typically only achievable with an in-house structural design team where all parties share a mutual goal.
Title 24 energy compliance will be designed for worst-case orientation. No mechanical and electrical engineering design is anticipated beyond typical line diagrams. Again, design efficiency will be a key mechanical and electrical design parameter. RRM is a leader in efficient, sustainable design. To this end, RRM will also provide an alternate specification to provide a higher level of sustainable design than the baseline code requirements provide.
We anticipate only one round of plan check revisions and resubmittal. RRM anticipates a single Citycoordinated review for all departments. The City will be responsible for the coordination of plan reviews.
As part of the construction document scope, an ADU application submission template will be developed to allow individual lot-specific submissions and alternate design submissions. The submission template will be developed using the City’s standard submittal process. Plans to be produced according to the following criteria:
Work Plan | SECTION 4
30 1. All designs shall fully comply with the 2022 California Residential Code, California Code of Regulations, Title 24, and Part 2.5. including the Electrical, Plumbing, Mechanical, Energy, Green Building and Fire Codes
2. All designs shall comply with the 2022 California Building Code (CBC), California Code of Regulations, Title 24, and Part 2 for structure(s) or elements(s) exceeding the design limitations in the CRC or specifically directed by the CRC to use the CBC.
3. Minimum Energy Compliance Design Criteria: State Title 24 Energy Compliance documentation in all four primary orientations (north-, south-, east-, and west-facing). a. Climate Zones: 12
b. Exterior Wall Insulation: R-15
c. Attic Insulation: R-30
d. Designed for both heating and cooling: 92 AFUE (Heating); 15 SEER (cooling)
4. Foundation Design Criteria:
The foundation design is generally site-specific, although the building code does allow for code minimums and the waiving of site-specific soil geotechnical investigations. The foundation design is provided for building sites that do not exceed a slope of one vertical to three horizontal units.
Discussions with the building official will be required to refine the approach for varying soil types. The design does not assume unstable soil or expansive clay soil:
a. Soil Bearing Pressure: 1,500 PSF (without Geotechnical Report) b. Lateral Bearing Pressure: 100 PCF
c. Foundation Depth Below Ground Surface: 18 inches min.
5. Fire Resistive Construction Details:
a. The proposed detached units should be anticipated to be located within four feet of a real or assumed property line on the rear or side elevation.
b. Therefore, for each of the proposed plan elevations, the rear and side elevations will be designed with options to comply with CRC Table R332.1 (1) Fire Resistance Protection/Rating of exterior Wall elements.
6. Wildlife Urban Interface details will be provided as alternate details when site locations are required.
DELIVERABLES:
EACH OF THE THREE (3) PLAN SETS WILL INCLUDE:
• PDF format plan set
• Jurisdictional-specific cover sheet
• Generic site plan with fillable information; no grading, stormwater, or utilities information five (5) feet beyond the unit
• Floor plan
• Foundation plans – slab on grade only.
• Floor framing plans if optioned
• Roof plan
• Roof truss plan and profiles - truss roof assumed; Framed roof would be additional cost. • Sections; as necessary, maximum of two (2) per unit
• External elevations: one (1) front, two (2) sides, and one (1) rear as plan typical elevations • Front exterior alternate style options; two (2) additional optional front elevations per plan, with associated details
SECTION 4 | Work Plan
City of Pleasant Hill | Proposal FOR Permit-Ready Accessory Dwelling Unit Program 31 • Renderings of exterior; one (1) exterior elevation rendering per style for marketing publication provided as individual graphic files, total of nine (9) • Recommended external and internal materials
• Architectural and structural details
• Mechanical, electrical, and plumbing plans; limited to line diagram electrical and mechanical • T24 Energy calculations (compliant for all building orientations) • No fire sprinklers plans are to be provided other than designating the requirement for fire sprinklers as applicable
• CALGreen (Title 24/Part 11) requirements sheet
• One (1) plan review cycle is anticipated
FINAL DELIVERY DOCUMENTS:
• 24 x 36 PDF file
• 11 x 17 PDF file (non-scalable)
• Color exterior renderings suitable for marketing and publication • Illustrative floor plan for marketing and publication • CAD files of the ADU plans without RRM title block, stamps or information MEETING:
• One (1) pre-submittal 90% set review meeting
MANAGE THE PROJECT
TASK A.7: PROJECT MANAGEMENT/COORDINATION
The foundation of RRM’s practice relies on expert and proactive project management. Successfully accomplishing each unique assignment within the needed timeframe and allocated budget is essential. RRM focuses on capturing a clear direction on final deliverables and end products at the beginning of a project, establishing a shared understanding of the project with the City and all team members. This provides an essential project “road map,” RRM develops a critical path schedule, monitoring and updating it regularly throughout the process. We make it a practice to provide regular status reports of project progress and closely coordinate with the County’s project manager and key consultant team members. RRM considers close project team collaboration as a key mechanism to ensure issues are well-vetted and fully addressed because better projects result from multiple perspectives. In addition, all product deliverables are reviewed internally for quality control purposes before the County submittal.
RRM has found establishing mutually agreeable, timely turnaround review times in managing a schedule is helpful. One practical approach can be for the City to provide one redlined, marked-up version of comments from its staff so that all comments are reconciled and expedited in the revision process. Early consultation with affected agencies and stakeholders is vital for a smooth and efficient process.
These approaches reduce potential surprises that can add costs, cause delays, and dilute consensus. In addition, the performance of project managers is evaluated in several ways:
• Monthly review of compliance with project budgets by task by RRM management and principals. Our Deltek Vision project Management and accounting software also allow project managers and principals Work Plan | SECTION 4
32 to track daily time entries and task budgets
• Ongoing oversight by the principal-in-charge regarding contract and schedule adherence as well as overall project progress
• Periodically, report cards are provided to clients to solicit feedback on the project manager and overall project performance
• Annually, project managers are evaluated on the quality of their performance • Throughout the project process, client feedback is sought by both RRM project managers and contract personnel to ensure satisfaction and provide the opportunity for adjustment if needed We take project management seriously and are committed to delivering on time and on budget.
WORK PROGRAM ASSUMPTIONS
• Meeting notices: The City is responsible for printing and distributing physical meeting notices when needed. If requested, the costs of providing printing and/or distribution of meeting notices would be on SECTION 4 | Work Plan
City of Pleasant Hill | Proposal FOR Permit-Ready Accessory Dwelling Unit Program 33 a time and materials basis.
• Meeting attendance: The project budget does not include attendance at public meetings. The costs of additional meeting attendance would be on time and materials. In addition, meetings are assumed to be conducted using a virtual format.
• Draft documents: A draft of each document will be provided to staff and revised based on a single set of consolidated comments providing clear direction.
• Printing: This budget assumes the County will be responsible for printing and distributing documents • Environmental review. The scope of work requested does not include environmental documentation or clearance pursuant to the California Environmental Quality Act. As such, environmental documentation and technical studies are not included in this work program. However, such documentation would be provided on a time and materials basis if requested.
• Ownership: Upon completion of the final plan review and delivery, the prototype plans will become the intellectual property of the county.
• Public Use: Upon final approval, an approved record set will be provided for county records as the Master Plan. Separate sets for public distribution will be provided with county logos and watermarked “APPROVED FOR USE IN PLEASANT HILL ONLY.”
• This proposal assumes the City will own and maintain the approved architect or engineer stamped originals, issue users unstamped copies, and require a hold harmless agreement to be signed by the end user. The wording suggested similar to ”By using these permit-ready accessory dwelling unit construction documents; the user agrees to release, hold harmless, and indemnify the City, its elected officials and employees, and the architect or engineer who prepared these construction documents from any claims, liabilities, suits, and demands on account of any injury, damage or loss to persons or property, including injury or death, or economic losses, arising out of the use of these construction documents.” Work Plan | SECTION 4
Exhibit “A-I-1” Professional Services Agreement
EXHIBIT "A-I"
FEDERAL CONTRACT PROVISIONS
During the performance of this Agreement, Consultant shall comply with all applicable federal laws and regulations including, but not limited to, the federal contract provisions in this Exhibit.
1. COMPLIANCE WITH U.S. DEPARTMENT OF THE TREASURY CORONAVIRUS
STATE AND LOCAL FISCAL RECOVERY FUND AWARD TERMS AND CONDITIONS (a) Maintenance of and Access to Records. Consultant shall maintain records and financial documents sufficient to evidence compliance with section 603(c) of ARPA, Treasury’s regulations implementing that section, and guidance issued by Treasury regarding the foregoing. Consultant agrees to provide the City, Treasury Office of Inspector General and the Government Accountability Office, or any of their authorized representatives access to any books, documents, papers, and records (electronic an otherwise) of the Consultant which are directly pertinent to this Agreement for the purposes of conducting audits or other investigations. Records shall be maintained by Consultant for a period of five (5) years after completion of the Project.
(b) Compliance with Federal Regulations. Consultant agrees to comply with the requirements of section 603 of ARPA, regulations adopted by Treasury pursuant to section 603(f) of ARPA, and guidance issued by Treasury regarding the foregoing. Consultant also agrees to comply with all other applicable federal statutes, regulations, and executive orders, including, without limitation, the following:
(i) Universal Identifier and System for Award Management (SAM), 2 C.F.R. Part 25, pursuant to which the award term set forth in Appendix A to 2 C.F.R. Part 25 is hereby incorporated by reference.
(ii) Reporting Subaward and Executive Compensation Information, 2 C.F.R. Part 170, pursuant to which the award term set forth in Appendix A to 2 C.F.R. Part 170 is hereby incorporated by reference.
(iii) OMB Guidelines to Agencies on Governmentwide Debarment and Suspension (Nonprocurement), 2 C.F.R. Part 180, including the requirement to include a term or condition in all lower tier covered transactions (contracts and subcontracts described in 2 C.F.R. Part 180, subpart B) that the award is subject to 2 C.F.R. Part 180 and Treasury’s implementing regulation at 31 C.F.R. Part 19. (iv) Recipient Integrity and Performance Matters, pursuant to which the award term set forth in 2 C.F.R. Part 200, Appendix XII to Part 200 is hereby incorporated by reference. (v) Governmentwide Requirements for Drug-Free Workplace, 31 C.F.R. Part 20. (vi) New Restrictions on Lobbying, 31 C.F.R. Part 21.
(vii) Uniform Relocation Assistance and Real Property Acquisitions Act of 1970 (42 U.S.C. §§ 4601-4655) and implementing regulations.
(c) Compliance with Federal Statutes and Regulations Prohibiting Discrimination.
Consultant agrees to comply with statutes and regulations prohibiting discrimination applicable to the SLFRF program including, without limitation, the following:
Exhibit “A-I-2” Professional Services Agreement
(i) Title VI of the Civil Rights Act of 1964 (42 U.S.C. §§ 2000d et seq.) and Treasury’s implementing regulations at 31 C.F.R. Part 22, which prohibit discrimination on the basis of race, color, or national origin under programs or activities receiving federal financial assistance. (ii) The Fair Housing Act, Title VIII of the Civil Rights Act of 1968 (42 U.S.C. §§ 3601 et seq.), which prohibits discrimination in housing on the basis of race, color, religion, national origin, sex, familial status, or disability.
(iii) Section 504 of the Rehabilitation Act of 1973, as amended (29 U.S.C. § 794), which prohibits discrimination on the basis of disability under any program or activity receiving federal financial assistance.
(iv) The Age Discrimination Act of 1975, as amended (42 U.S.C. §§ 6101 et seq.), and Treasury’s implementing regulations at 31 C.F.R. Part 23, which prohibit discrimination on the basis of age in programs or activities receiving federal financial assistance. (v) Title II of the Americans with Disabilities Act of 1990, as amended (42 U.S.C. §§ 12101 et seq.), which prohibits discrimination on the basis of disability under programs, activities, and services provided or made available by state and local governments or instrumentalities or agencies thereto. (d) False Statements. Consultant understands that making false statements or claims in connection with the SLFRF program is a violation of federal law and may result in criminal, civil, or administrative sanctions, including fines, imprisonment, civil damages and penalties, debarment from participating in federal awards or contracts, and/or any other remedy available by law. (e) Hatch Act. If Consultant is a public agency, Consultant agrees to comply, as applicable, with the requirements of the Hatch Act (5 U.S.C. section 1501-1508 and 7324-7328), which limit certain political activities of State or local government employees whose principal employment is in connection with an activity financed in whole or in part by this federal assistance. (f) Protections for Whistleblowers.
(i) In accordance with 41 U.S.C. § 4712, Consultant may not discharge, demote, or otherwise discriminate against an employee in reprisal for disclosing to any of the list of persons or entities provided below, information that the employee reasonably believes is evidence of gross mismanagement of a federal contract or grant, a gross waste of federal funds, an abuse of authority relating to a federal contract or grant, a substantial and specific danger to public health or safety, or a violation of law, rule, or regulation related to a federal contract (including the competition for or negotiation of a contract) or grant. (ii) The list of persons and entities referenced in the paragraph above includes the following:
(1) A member of Congress or a representative of a committee of Congress; (2) An Inspector General;
(3) The Government Accountability Office;
(4) A Treasury employee responsible for contract or grant oversight or management;
Exhibit “A-I-3” Professional Services Agreement
(5) An authorized official of the Department of Justice or other law enforcement agency;
(6) A court or grand jury; or
(7) A management official or other employee of Consultant, or a subcontractor who has the responsibility to investigate, discover, or address misconduct. (g) Increasing Seat Belt Use in the United States. Pursuant to Executive Order 13043, 62 FR 19217 (Apr. 18, 1997), Consultant is encouraged to adopt and enforce on-the-job seat belt policies and programs for their employees when operating company-owned, rented or personally owned vehicles, and encourage its subcontractors to do the same
(h) Reducing Text Messaging While Driving. Pursuant to Executive Order 13513, 74 FR 51225 (Oct. 6, 2009), Consultant should encourage its employees and subcontractors to adopt and enforce policies that ban text messaging while driving, and Consultant should establish workplace safety policies to decrease accidents caused by distracted drivers.
(i) Assurances of Compliance with Civil Rights Requirements. The Civil Rights Restoration Act of 1987 provides that the provisions of this assurance apply to the Agreement, including, but not limited to, the following:
(i) Consultant ensures its current and future compliance with Title VI of the Civil Rights Act of 1964, as amended, which prohibits exclusion from participation, denial of the benefits of, or subjection to discrimination under programs and activities receiving federal funds, of any person in the United States on the ground of race, color, or national origin (42 U.S.C. § 2000d et seq.), as implemented by the Department of the Treasury Title VI regulations at 31 CFR Part 22 and other pertinent executive orders such as Executive Order 13166; directives; circulars; policies; memoranda and/or guidance documents.
(ii) Consultant acknowledges that Executive Order 13166, “Improving Access to Services for Persons with Limited English Proficiency (LEP),” seeks to improve access to federally assisted programs and activities for individuals who, because of national origin, are limited in their English proficiency. Consultant understands that the denial of access to persons to its programs, services and activities because of their limited proficiency in English is a form of national origin discrimination prohibited under Title VI of the Civil Rights Act of 1964. Accordingly, Consultant shall initiate reasonable steps, or comply with Treasury’s directives, to ensure meaningful access to its programs, services and activities to LEP persons. Consultant understands and agrees that meaningful access may entail providing language assistance services, including oral interpretation and written translation where necessary to ensure effective communication in the Project.
(iii) Consultant agrees to consider the need for language services for LEP persons during development of applicable budgets and when conducting programs, services and activities. As a resource, the Department of the Treasury has published its LEP guidance at 70 FR 6067. For more information on LEP, please visit http://www.lep.gov.
(iv) Consultant acknowledges and agrees that compliance with this assurance constitutes a condition of continued receipt of federal financial assistance and is binding upon Consultant and Consultant’s successors, transferees and assignees for the period in which such assistance is provided.
Exhibit “A-I-4” Professional Services Agreement
(v) Consultant agrees to incorporate the following language in every contract or agreement subject to Title VI and its regulations between the Consultant and the Consultant’s subcontractors, successors, transferees and assignees:
The subcontractor, successor, transferee and assignee shall comply with Title VI of the Civil Rights Act of 1964, which prohibits recipients of federal financial assistance from excluding from a program or activity, denying benefits of, or otherwise discriminating against a person on the basis of race, color, or national origin (42 U.S.C. § 2000d et seq.), as implemented by Department of the Treasury Title VI regulations, 31 CFR Part 22, which are herein incorporated by reference and made a part of this contract (or agreement). Title VI also extends protection to persons with “Limited English proficiency” in any program or activity receiving federal financial assistance, 42 U.S.C. § 2000d et seq., as implemented by Department of the Treasury Title VI regulations, 31 CFR Part 22, which are herein incorporated by reference and made a part of this contract (or agreement). (vi) Consultant understands and agrees that if any real property or structure is provided or improved with the aid of federal financial assistance by the Department of the Treasury, this assurance obligates the Consultant, or in the case of a subsequent transfer, the transferee, for the period during which the real property or structure is used for a purpose for which the federal financial assistance is extended or for another purpose involving the provision of similar services or benefits. If any personal property is provided, this assurance obligates the Consultant for the period during which it retains ownership or possession of the property.
(vii) Consultant shall cooperate in any enforcement or compliance review activities by the Department of the Treasury of the aforementioned obligations. Enforcement may include investigation, arbitration, mediation, litigation, and monitoring of any settlement agreements that may result from these actions. Consultant shall comply with information requests, on-site compliance reviews, and reporting requirements.
(viii) Consultant shall maintain a complaint log and inform the Department of the Treasury of any accusations of discrimination on the grounds of race, color, or national origin, and limited English proficiency covered by Title VI of the Civil Rights Act of 1964 and implementing regulations and provide, upon request, a list of all such reviews or proceedings based on the complaint, pending or completed, including outcome. Consultant must also inform the Department of the Treasury if Consultant has received no complaints under Title VI.
(ix) Consultant must provide documentation of an administrative agency’s or court’s findings of non-compliance of Title VI and efforts to address the non-compliance, including any voluntary compliance or other agreements between the Consultant and the administrative agency that made the finding. If the Consultant settles a case or matter alleging such discrimination, Consultant must provide documentation of the settlement. If Consultant has not been the subject of any court or administrative agency finding of discrimination, please so state.
(x) If Consultant makes sub-awards to other agencies or other entities, Consultant is responsible for assuring that sub-recipients also comply with Title VI and all of the applicable authorities covered in this assurance.
2. REQUIRED CONTRACT PROVISIONS IN ACCORDANCE WITH APPENDIX II TO PART 200 – CONTRACT PROVISIONS FOR NON-FEDERAL ENTITY CONTRACTS UNDER
FEDERAL AWARDS
(a) Appendix II to Part 200 (A); Appendix II to Part 200 (B): Remedies for Breach; Termination for Cause/Convenience. The Agreement include remedies for breach and termination for cause and convenience.
Exhibit “A-I-5” Professional Services Agreement
(b) Appendix II to Part 200 (C) – Equal Employment Opportunity: Except as otherwise provided under 41 C.F.R. Part 60, if this Agreement meets the definition of a “federally assisted construction contract” in 41 C.F.R. § 60-1.3, then Consultant shall comply with the following equal opportunity clause, in accordance with Executive Order 11246 of September 24, 1965 entitled “Equal Employment Opportunity,” as amended by Executive Order 11375 of October 13, 1967 and implementation regulations at 41 C.F.R. Chapter 60:
(i) Consultant will not discriminate against any employee or applicant for employment because of race, color, religion, sex, sexual orientation, gender identity, or national origin. The Consultant will take affirmative action to ensure that applicants are employed, and that employees are treated during employment without regard to their race, color, religion, sex, sexual orientation, gender identity, or national origin. Such action shall include, but not be limited to the following: Employment, upgrading, demotion, or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. The Consultant agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided setting forth the provisions of this nondiscrimination clause. (ii) Consultant will, in all solicitations or advertisements for employees placed by or on behalf of the Consultant, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, or national origin. (iii) Consultant will not discharge or in any other manner discriminate against any employee or applicant for employment because such employee or applicant has inquired about, discussed, or disclosed the compensation of the employee or applicant or another employee or applicant. This provision shall not apply to instances in which an employee who has access to the compensation information of other employees or applicants as a part of such employee's essential job functions discloses the compensation of such other employees or applicants to individuals who do not otherwise have access to such information, unless such disclosure is in response to a formal complaint or charge, in furtherance of an investigation, proceeding, hearing, or action, including an investigation conducted by the employer, or is consistent with the Consultant's legal duty to furnish information. (iv) Consultant will send to each labor union or representative of workers with which he has a collective bargaining agreement or other contract or understanding, a notice to be provided advising the said labor union or workers' representatives of the Consultant's commitments under this section, and shall post copies of the notice in conspicuous places available to employees and applicants for employment. (v) Consultant will comply with all provisions of Executive Order 11246 of September 24, 1965, and of the rules, regulations, and relevant orders of the Secretary of Labor. (vi) Consultant will furnish all information and reports required by Executive Order 11246 of September 24, 1965, and by rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records, and accounts by the administering agency and the Secretary of Labor for purposes of investigation to ascertain compliance with such rules, regulations, and orders.
(vii) In the event of the Consultant's noncompliance with the nondiscrimination clauses of this Agreement or with any of the said rules, regulations, or orders, this Agreement may be canceled, terminated, or suspended in whole or in part and the Consultant may be declared ineligible for further Government contracts or federally assisted construction contracts in accordance with procedures authorized in Executive Order 11246 of September 24, 1965, and such other sanctions may be imposed and remedies Exhibit “A-I-6” Professional Services Agreement
invoked as provided in Executive Order 11246 of September 24, 1965, or by rule, regulation, or order of the Secretary of Labor, or as otherwise provided by law. (viii) Consultant will include the portion of the sentence immediately preceding paragraph (i) and the provisions of paragraphs (i) through (vii) in every subcontract or purchase order unless exempted by rules, regulations, or orders of the Secretary of Labor issued pursuant to section 204 of Executive Order 11246 of September 24, 1965, so that such provisions will be binding upon each subcontractor or vendor. The Consultant will take such action with respect to any subcontract or purchase order as the administering agency may direct as a means of enforcing such provisions, including sanctions for noncompliance:
Provided, however, that in the event a Consultant becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of such direction by the administering agency, the Consultant may request the United States to enter into such litigation to protect the interests of the United States.
The applicant further agrees that it will be bound by the above equal opportunity clause with respect to its own employment practices when it participates in federally assisted construction work: Provided, That if the applicant so participating is a State or local government, the above equal opportunity clause is not applicable to any agency, instrumentality or subdivision of such government which does not participate in work on or under the Agreement.
The applicant agrees that it will assist and cooperate actively with the administering agency and the Secretary of Labor in obtaining the compliance of contractors and subcontractors with the equal opportunity clause and the rules, regulations, and relevant orders of the Secretary of Labor, that it will furnish the administering agency and the Secretary of Labor such information as they may require for the supervision of such compliance, and that it will otherwise assist the administering agency in the discharge of the agency's primary responsibility for securing compliance.
The applicant further agrees that it will refrain from entering into any contract or contract modification subject to Executive Order 11246 of September 24, 1965, with a contractor debarred from, or who has not demonstrated eligibility for, Government contracts and federally assisted construction contracts pursuant to the Executive Order and will carry out such sanctions and penalties for violation of the equal opportunity clause as may be imposed upon contractors and subcontractors by the administering agency or the Secretary of Labor pursuant to Part II, Subpart D of the Executive Order. In addition, the applicant agrees that if it fails or refuses to comply with these undertakings, the administering agency may take any or all of the following actions: Cancel, terminate, or suspend in whole or in part this grant (contract, loan, insurance, guarantee); refrain from extending any further assistance to the applicant under the program with respect to which the failure or refund occurred until satisfactory assurance of future compliance has been received from such applicant; and refer the case to the Department of Justice for appropriate legal proceedings. (c) Appendix II to Part 200 (D) – Davis-Bacon Act: Not applicable to this Agreement since it is funded by SLFRF.
(d) Appendix II to Part 200 (D) – Copeland “Antti-Kickback” Act: Not applicable to this Agreement since it is funded by SLFRF.
(e) Appendix II to Part 200 (E) – Contract Work Hours and Safety Standards Act:
(i) If this Agreement is in excess of $100,000 and involves the employment of mechanics or laborers, Consultant shall comply with 40 U.S.C. 3702 and 3704, as supplemented by Department of Labor regulations (29 C.F.R. Part 5). Under 40 U.S.C. 3702, each contractor must be Exhibit “A-I-7” Professional Services Agreement
required to compute the wages of every mechanic and laborer on the basis of a standard work week of 40 hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of 40 hours in the work week. The requirements of 40 U.S.C. 3704 are applicable to construction work and provide that no laborer or mechanic must be required to work in surroundings or under working conditions which are unsanitary, hazardous or dangerous. These requirements do not apply to the purchases of supplies or materials or articles ordinarily available on the open market, or contracts for transportation or transmission of intelligence.
(ii) Overtime Requirements. No contractor or subcontractor contracting for any part of the Agreement work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek.
(iii) Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (ii) of this section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (ii) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (ii) of this section.
(iv) Withholding for unpaid wages and liquidated damages. The City shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the Consultant or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (iii) of this section.
(v) Subcontracts. The Consultant or subcontractor shall insert in any subcontracts the clauses set forth in paragraph (ii) through (v) of this Section and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The Consultant shall be responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (ii) through (v) of this Section.
(f) Appendix II to Part 200 (F) – Rights to Inventions Made Under a Contract or Agreement:
(i) If the Federal award meets the definition of “funding agreement” under 37 C.F.R. § 401.2(a) and the non-Federal entity wishes to enter into a contract with a small business firm or nonprofit organization regarding the substitution of parties, assignment or performance of experimental, developmental, or research work under that “funding agreement,” the non-Federal entity must comply with the requirements of 37 C.F.R. Part 401 (Rights to Inventions Made by Nonprofit Organizations and Small Business Firms Under Government Grants, Contracts and Cooperative Agreements), and any implementing regulations issued by the Federal awarding agency.
Exhibit “A-I-8” Professional Services Agreement
(ii) The regulation at 37 C.F.R. § 401.2(a) currently defines “funding agreement” as any contract, grant, or cooperative agreement entered into between any Federal agency, other than the Tennessee Valley Authority, and any contractor for the performance of experimental, developmental, or research work funded in whole or in part by the Federal government. This term also includes any assignment, substitution of parties, or subcontract of any type entered into for the performance of experimental, developmental, or research work under a funding agreement as defined in the first sentence of this paragraph. (g) Appendix II to Part 200 (G) – Clean Air Act and Federal Water Pollution Control Act: If this Agreement is in excess of $150,000, Consultant shall comply with all applicable standards, orders, or requirements issued pursuant to the Clean Air Act (42 U.S.C. 7401-7671q) and the Federal Water Pollution Control Act as amended (33 U.S.C. 1251-1387).
(i) Pursuant to the Clean Air Act, (1) Consultant agrees to comply with all applicable standards, orders or regulations issued pursuant to the Clean Air Act, as amended, 42 U.S.C. § 7401 et seq., (2) Consultant agrees to report each violation to the City and understands and agrees that the City will, in turn, report each violation as required to assure notification to the Federal awarding agency and the appropriate Environmental Protection Agency Regional Office, and (3) Consultant agrees to include these requirements in each subcontract exceeding $150,000.
(ii) Pursuant to the Federal Water Pollution Control Act, (1) Consultant agrees to comply with all applicable standards, orders or regulations issued pursuant to the Federal Water Pollution Control Act, as amended, 33 U.S.C. 1251 et seq., (2) Consultant agrees to report each violation to the City and understands and agrees that the City will, in turn, report each violation as required to assure notification to the Federal awarding agency and the appropriate Environmental Protection Agency Regional Office, and (3) Consultant agrees to include these requirements in each subcontract exceeding $150,000. (h) Appendix II to Part 200 (H) – Debarment and Suspension: A contract award (see 2 C.F.R. § 180.220) must not be made to parties listed on the government wide exclusions in the System for Award Management (SAM), in accordance with the OMB guidelines at 2 CFR 180 that implement Executive Orders 12549 (3 C.F.R. part 1986 Comp., p. 189) and 12689 (3 C.F.R. part 1989 Comp., p. 235), “Debarment and Suspension.” SAM Exclusions contains the names of parties debarred, suspended, or otherwise excluded by agencies, as well as parties declared ineligible under statutory or regulatory authority other than Executive Order 12549.
(i) This Agreement is a covered transaction for purposes of 2 C.F.R. pt. 180 and 2 C.F.R. pt. 3000. As such Consultant is required to verify that none of the Consultant, its principals (defined at 2 C.F.R. § 180.995), or its affiliates (defined at 2 C.F.R. § 180.905) are excluded (defined at 2 C.F.R. § 180.940) or disqualified (defined at 2 C.F.R. § 180.935). (ii) Consultant must comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C and must include a requirement to comply with these regulations in any lower tier covered transaction it enters into.
(iii) This certification is a material representation of fact relied upon by City. If it is later determined that Consultant did not comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C, in addition to remedies available to the City, the Federal Government may pursue available remedies, including but not limited to suspension and/or debarment. (iv) Consultant warrants that it is not debarred, suspended, or otherwise excluded from or ineligible for participation in any federal programs. Consultant also agrees to verify that all subcontractors performing work under this Agreement are not debarred, disqualified, or otherwise Exhibit “A-I-9” Professional Services Agreement
prohibited from participation in accordance with the requirements above. Consultant further agrees to notify the City in writing immediately if Consultant or its subcontractors are not in compliance during the term of this Agreement.
(i) Appendix II to Part 200 (I) – Byrd Anti-Lobbying Act: If this Agreement is in excess of $100,000, Consultant shall have submitted and filed the required certification pursuant to the Byrd AntiLobbying Amendment (31 U.S.C. § 1353). If at any time during the Agreement term funding exceeds $100,000.00, Consultant shall file with the City the Federal Standard Form LLL titled “Disclosure Form to Report Lobbying.” Contractors that apply or bid for an award exceeding $100,000 must file the required certification. Each tier certifies to the tier above that it will not and has not used Federal appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant or any other award covered by 31 U.S.C. 1352.
Each tier must also disclose any lobbying with non-Federal funds that takes place in connection with obtaining any Federal award. Such disclosures are forwarded from tier to tier up to the recipient who in turn will forward the certification(s) to the awarding agency. (j) Appendix II to Part 200 (J) – §200.323 Procurement of Recovered Materials:
(i) Consultant shall comply with section 6002 of the Solid Waste Disposal Act, as amended by the Resource Conservation and Recovery Act. The requirements of Section 6002 include procuring only items designated in guidelines of the Environmental Protection Agency (EPA) at 40 C.F.R. part 247 that contain the highest percentage of recovered materials practicable, consistent with maintaining a satisfactory level of competition, where the purchase price of the item exceeds $10,000 or the value of the quantity acquired during the preceding fiscal year exceeded $10,000; procuring solid waste management services in a manner that maximizes energy and resource recovery; and establishing an affirmative procurement.
(ii) In the performance of this Agreement, the Consultant shall make maximum use of products containing recovered materials that are EPA-designated items unless the product cannot be acquired: Competitively within a timeframe providing for compliance with the contract performance schedule; Meeting contract performance requirements; or at a reasonable price. (iii) Information about this requirement, along with the list of EPA-designate items, is available at EPA’s Comprehensive Procurement Guidelines web site, https://www.epa.gov/smm/comprehensive-procurement-guideline-cpg-program. (iv) Consultant also agrees to comply with all other applicable requirements of Section 6002 of the Solid Waste Disposal Act.”
(k) Appendix II to Part 200 (K) – §200.216 Prohibition on Certain Telecommunications and Video Surveillance Services or Equipment:
(i) Consultant shall not contract (or extend or renew a contract) to procure or obtain equipment, services, or systems that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system funded under this Agreement. As described in Public Law 115–232, section 889, covered telecommunications equipment is telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities).
Exhibit “A-I-10” Professional Services Agreement
(1) For the purpose of public safety, security of government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities).
(2) Telecommunications or video surveillance services provided by such entities or using such equipment.
(3) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of the National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country. (ii) See Public Law 115-232, section 889 for additional information. (l) Appendix II to Part 200 (L) – §200.322 Domestic Preferences for Procurement:
(i) Consultant shall, to the greatest extent practicable, purchase, acquire, or use goods, products, or materials produced in the United States (including but not limited to iron, aluminum, steel, cement, and other manufactured products). The requirements of this section must be included in all subcontracts
(ii) For purposes of this section:
(1) “Produced in the United States’’ means, for iron and steel products, that all manufacturing processes, from the initial melting stage through the application of coatings, occurred in the United States.
(2) ‘‘Manufactured products’’ means items and construction materials composed in whole or in part of nonferrous metals such as aluminum; plastics and polymer-based products such as polyvinyl chloride pipe; aggregates such as concrete; glass, including optical fiber; and lumber.
Exhibit “B”-1 Professional Services Agreement
EXHIBIT "B"
SCHEDULE OF SERVICES
38 Contract Initiation
Task A.1: Initiation Meeting
Task A.2: Data Gathering and Document Research
Task A.3: Preliminary (30%) ADU Design
Task A.4: Schematic (65%) ADU Design
Task A.5: Public Meetings (Optional Task)
Task A.6: Document Preparation and Plan Review
Task A.7 - A.8: Optional Engineering Tasks
Task A.9: Project Management/Coordination
Meeting
Duration
ADU PROTOTYPES
RECOMMENDED PROJECT SCHEDULE
City of Pleasant Hill
ADU Prototype Plans June July Aug Sept Oct Nov Dec
SECTION 5 | Cost Proposal & Project Schedule
Exhibit “C”-1 Professional Services Agreement
EXHIBIT "C"
COMPENSATION
City of Pleasant Hill | Proposal FOR Permit-Ready Accessory Dwelling Unit Program 37 RRM
SCOTT
MARTIN
RRM
RANDY
RUSSOM
RRM
JESSICA
MEADOWS
RRM
JOEY
COX
RRM
ARCH STAFF
RRM
ENG STAFF
260 $ per hour 250 $ per hour 210 $ per hour 135 $ per hour 130 $ per hour 130 $ per hour
ESTABLISH A STRONG FOUNDATION FEE
TYPE
ESTIMATED
FEE
A.1 Project Initiation / Kick Off T&M NTE $ 1,410 1 $260 2 $500 1 $380 2 $270 0 $0 0 $0 A.2 Data Gathering and Document Reasearch T&M NTE $ 2,080 0 $0 2 $500 0 $0 4 $540 8 $1,040 0 $0 Total: $ 3,490
ADU DESIGN FEE
TYPE
ESTIMATED
FEE
A.3 Preliminary (30%) ADU Design T&M NTE $ 7,260 2 $520 8 $2,000 0 $0 12 $1,620 24 $3,120 0 $0 A.4 Schematic (65%) ADU Design T&M NTE $ 11,840 2 $520 12 $3,000 2 $420 20 $2,700 40 $5,200 0 $0 A.5 Public Hearings (Optional Below) T&M NTE $ 2,560 $0 6 $1,500 $0 4 $540 4 $520 $0 Value: $ 21,660
ADU CONSTRUCTION DOCUMENTS FEE
TYPE
ESTIMATED
FEE
A.6 Document Preparation and Plan Review T&M NTE $ 49,500 0 $0 24 $6,000 20 $4,200 60 $8,100 120 $15,600 120 $15,600 Value: $ 49,500
MANAGE THE PROJECT FEE
TYPE
ESTIMATED
FEE
A.7 Project Management/Coordination T&M NTE $ 6,840 0 $0 24 $6,000 4 $840 0 $0 0 $0 0 $0 Value: $ 6,840
$ 81,490
$ 2,500
$ 8,400
$ 92,390
OPTIONAL TASKS FEE
TYPE
ESTIMATED
FEE
A.5 Additional Public Hearings (Optional) T&M NTE $ 2,560 0 $0 6 $1,500 0 $0 4 $540 4 $520 0 $0 Value: $ 2,560
Additional plans can be developed as part of this scope for aproximately $18,000 per plan.
FEE SCHEDULE
City of Pleasant Hill
ADU Prototype Plans
May 2, 2024
Architect/Project
Manager Structural Engineer Principal/Design Director
Engineering Production
Staff
Architectural
Production Staff Job Captain
Fee Footnote
Estimated fees for tasks shown as “Time and Materials - Not to Exceed" (T&M/NTE) are provided for informational purposes only. Amounts billed for these tasks, which will reflect actual hours, will not be exceeded without prior approval by the client.
Reimbursable Expenses
Incidental expenses incurred by RRM Design Group or any subconsultant it may hire to perform services for this project are reimbursed by the client at actual cost plus 10% to cover its overhead and administrative expenses.
Adjustment to Hourly Billing Rates
RRM reserves the right to adjust hourly rates on an annual basis.
Subtotal
Estimated Project Total
10 % Contingency
Reimbursable Expenses
Cost Proposal & Project Schedule | SECTION 5
36 EXHIBIT A-1 SCHEDULE 1
Bill Rate Ranges
Subject to change effective March 1st each year
ARCHITECTURE INTERIOR DESIGN
Intern $ 54 - $ Designer I 91 $ 72 - $ 109
Designer I $ 81 - $ Designer II 109 $ 88 - $ 133
Designer II $ 88 $ Interior Designer I 130 $ 95 - $ 140 Designer III $ 105 - $ Interior Designer II 167 $ 105 - $ 168 Job Captain $ 105 - $ Interior Designer III 167 $ 125 - $ 189 Architect $ 111 - $ Senior Interior Designe 170 r $ 135 - $ 210 Project Designer $ 123 - $ 193
Project Manager $ 128 - $ 207 LANDSCAPE ARCHITECTURE
Project Architect 123$ - $ Intern 193 $ 54 - $ 91
Senior Designer $ 150 - $ Assistant Designe 242 r $ 81 - $ 112 Senior Architect $ 150 - $ Associate Designe 256 r $ 89 - $ 137 Senior Project Manager $ 153 - $ Designe 263 r $ 102 - $ 150 Associate Manager of Architecture $ 159 - $ Senior Designe 245 r $ 116 - $ 175 Design Director $ 179 - $ Landscape Architect 301 $ 105 - $ 158 Manager of Architecture $ 185 - $ Senior Landscape Architect 301 $ 128 - $ 188 Director of Architecture $ 197 - $ Principal Landscape Architect 322 $ 153 - $ 252 Principal $ 204 - $ Design Director (Landscape) 368 $ 153 - $ 256 Managing Partner $ 220 - $ Manager of Landscape Architecture 442 $ 162 - $ 259 Principal $ 204 - $ 368
ENGINEERING Managing Partner $ 220 - $ 442
CIVIL ENGINEERING
Construction Inspector $ 100 - $ 188 PLANNING
Designer I $ 75 - $ Intern 105 $ 54 - $ 91
Designer II $ 85 - $ GIS Specialist 135 $ 80 - $ 165
Associate Engineer $ 126 - $ Senior GIS Specialist 186 $ 105 - $ 200 Senior Associate Engineer $ 143 - $ Assistant Planne 232 r $ 96 - $ 139 Engineer I $ 103 - $ Associate Planne 155 r $ 114 - $ 182 Engineer II $ 116 - $ Urban Designe 182 r $ 114 - $ 182 Project Engineer $ 139 - $ Senior Planne 205 r $ 145 - $ 222 Senior Project Engineer $ 156 - $ Senior Urban Designe 256 r $ 145 - $ 222 Project Manager $ 172 - $ Supervisor of Planning and Urban Design 271 $ 152 - $ 229 Manager of Engineering Services $ 195 - $ Principal Planne 309 r $ 177 - $ 270 Principal $ 204 - $ Manager of Planning 368 $ 190 - $ 284 Managing Partner $ 220 - $ Principal 442 $ 204 - $ 368
STRUCTURAL ENGINEERING Managing Partner $ 220 - $ 442
Designer I $ 75 - $ 120
Designer II $ 87 - $ 136 CORPORATE SERVICES
Designer III $ 102 - $ File Clerk/Administrative Support 150 $ 60 - $ 88 Senior Designer $ 122 - $ Receptionist 197 $ 60 - $ 91
Engineer I $ 99 - $ Administrative Assistant 146 $ 65 - $ 105 Engineer II $ 117 - $ Administrative Coordinato 182 r $ 81 - $ 140 Project Engineer $ 139 - $ Office Coordinato 205 r $ 81 - $ 140 Senior Project Engineer $ 156 - $ Office Manage 255 r $ 116 - $ 175 Project Manager $ 166 - $ Marketing Assistant 263 $ 60 - $ 91 Manager of Engineering Services $ 189 - $ Marketing Coordinato 301 r $ 75 - $ 126 Principal $ 204 - $ Marketing Specialist 368 $ 101 - $ 168 Managing Partner $ 220 - $ Senior Marketing Specialist 442 $ 116 - $ 203 SURVEYING (Crew Rates) Business Development & Pursuits Supervisor $ 117 - $ 210 REGULAR Marketing Manager $ 137 - $ 256
One person w/ GPS or Robotic Workstation 170 $ - $ CEO 225 $ 276 - $ 546 Two person $ 230 - $ 380
Three person $ 310 - $ 485
PREVAILING WAGE
One person w/ GPS or Robotic Workstation 260 $ - $ 360
Two person $ 325 - $ 370
Three person $ 410 - $ 595
Rev 3/1/2024
BILL RATE RANGES
Subject to change effective March 1st each year
SECTION 5 | Cost Proposal & Project Schedule