February 20, 2024, Item #2
DATE:
TO:
FROM:
CONTACT:
SUBJECT:
Summary:
AGENDA REPORT CityofPoway
February 20, 2024
Honorable Mayor and Members of the City Council
Robert Manis, Director of Development Services!,{),
< •'
Andrea Thomas, Associate Civil Engineer f4
(858) 668-4605 or [email protected] •
CITY COUNCIL
Award of Contract to Unified Field Services Corporation for the R-4 and R-7 Reservoir Rehabilitation Project, Bid No. 24-002, Appropriation of Additional Funds and Determination the Project is Categorically Exempt from the California Environmental Quality Act (CEQA)
This action will award a construction contract for the rehabilitation of two reservoirs, R-4 and R-7. The exterior of reservoir R-4 will be recoated and safety upgrades will be completed. The interior of reservoir R-7 will be recoated, structural repairs made, and safety upgrades completed.
Recommended Action:
It is recommended the City Council:
1) Award the contract for the R-4 and R-7 Reservoir Rehabilitation project to Unified Field Services Corporation, in the amount of $1,228,073.00 and authorize the City Manager to execute the contract (Attachment A);
2) Appropriate additional funds in the amount of $200,000.00 from the Water Fund (5100) for construction of the R-4 and R-7 Reservoir Rehab project (CIP #WT034); and 3) Make a determination the Project is Categorically Exempt from the California Environmental Quality Act (CEQA).
Discussion:
The R-4 and R-7 reservoirs have been identified as requiring rehabilitation of major components in the Water Distribution System Maintenance and Rehabilitation Assessment, published by Carollo Engineers in 2014. Reservoir R-4 will receive a new exterior coating, new vents, updated fall restraint systems, and a new liquid level indicator. Reservoir R-7 will receive a new interior coating, additional vent, roof rafter repairs and replacement, updated fall restraint systems, integrated overflow air gap, and a new cathodic protection system.
The contract time for this project is 90 working days with an engineer's estimate of $1,050,000.00.
Bids were opened on January 25, 2024. The following six bids were received:
1 of 11
February 20, 2024, Item #2
Company
Total
Bid
Amount
Unified
Field
Services
Corporation
$1,228,073.00
Utility
Service
Co.,
Inc.
$1,252,800.00
Advanced
Industrial
Services,
Inc
.
$1,285,150.00
AMP
United,
LLC
$1,506,420.00
Houalla
Enterprises
&
Metro
Builders
$1,965,813.00
Abhe
&
Svoboda,
Inc
.
$2,256,245.00
The
lowest
responsive
bidder,
Unified
Field
Services
Corporation,
is
recommended
for
the
award
of
this
contract.
Since
the
lowest
bid
is
higher
than
the
available
budget,
an
additional
appropriation
is
required. Environmental
Review:
The
proposed
project
is
Categorically
Exempt
from
CEQA
as
a Class
1 Categorical
Exemption,
pursuant
to
Section
15301
of
the
CEQA
Guidelines,
in
that
the
project
involves
the
rehabilitation
of
existing
potable
water
supply
reservoirs.
Fiscal
Impact:
Approval
of
this
item
will
result
in
an
additional
appropriation
of
$200,000.00
from
the
Water
Fund
(5100)
to
the
R-4
and
R-7
Reservoir
Rehabilitation
project
(WT034)
. There
is
$1,155,840.35
of
unencumbered
funds
currently
available
in
WT034
. The
revised
budget
of
$1,355,840.35
will
include
the
cost
for
the
construction
contract,
10%
construction
contingency
and
the
cost
for
required
special
inspections. Public
Notification:
None. Attachments: A.
Contract
Reviewed/Approved
By:
~~Ka~
Assistant
City
Manager
2 of
11 Reviewed
By:
Alan
Fenstermacher
City
Attorney
e
City
Manager
February 20, 2024, Item #2
SECTION
8 CONSTRUCTION
CONTRACT
CITY
OF
POWAY
RESERVOIR
R-4
AND
R-7
REHABILITATION
This
Contract
made
and
entered
into
this
__
day
of
_____
, 2024,
by
and
between
City
of
Poway
, a municipal
corporation
of
the
State
of
California
, hereinafter
referred
to
as
"City"
and
-----------------------
,
hereinafter
referred
to
as
"Contractor."
The
City
and
the
Contractor,
for
the
consideration
hereinafter
named
, mutually
agree
as
follows
:
1. The
complete
Contract
includes
all
of
the
Contract
Documents,
which
are
incorporated
herein
by
this
reference
, and
include:
a.
This
Contract
b.
Contract
Addenda
c.
Contract
Change
Orders
d.
Instructions
to
Bidders,
Proposal
Requirements
and
Conditions
e.
Contract
Specifications
f.
Contract
Plans
g.
General
Condition
h.
Special
Conditions
i.
Standard
Specification
for
Public
Works,
most
current
edition
2. The
Contract
Documents
are
complementary,
and
that
which
is
required
by
one
shall
be
as
binding
as
if required
by
all
.
3. Contractor
shall
provide
and
furnish
all
labor,
materials,
necessary
tools,
expendable
equipment,
and
all
utility
and
transportation
services
required
for
the
following
work
of
improvement:
The
project
scope
includes
recoating
the
exterior
of
R-4,
recoating
and
rehabilitating
the
structure
and
interior
of
R-7,
repairs
to
the
foundations,
and
multiple
safety
retrofits
on
both
tanks.
4. Contractor
agrees
to
perform
all
the
said
work
and
furnish
all
the
said
materials
at
their
own
cost
and
expense
that
are
necessary
to
construct
and
complete
in
strict
conformance
with
Contract
Documents
and
to
the
satisfaction
of
the
City
Engineer,
the
work
hereinafter
set
forth
in
accordance
with
the
Contract
adopted
by
the
City
Council.
3 of
11 ATTACHMENT
A
February 20, 2024, Item #2
5. City
agrees
to
pay
and
Contractor
agrees
to
accept
in
full
payment
for
performance
of
this
work
of
improvement
as
described,
the
stipulated
sum
of
$ ________
the
"Contract
Price."
City
agrees
to
make
progress
payments
and
final
payment
in
accordance
with
the
method
set
forth
in
the
Special
Provisions.
6. Contractor
agrees
to
commence
construction
of
the
work
provided
for herein
within
Fifteen
(15)
Calendar
Days
after
the
date
specified
in
the
Notice
to
Proceed,
and
to
continue
diligently
in
strict
conformance
with
Contract
Documents
and
without
interruption,
and
to
complete
the
construction
thereof
within
90 Working
Days
after
the
date
specified
in
the
Notice
to
Proceed.
7. Time
is
of
the
essence
of
this
Contract,
and
it
is
agreed
that
it
would
be
impracticable
or
extremely
difficult
to
ascertain
the
extent
of
actual
loss
or
damage
which
the
City
will
sustain
by
reason
of
any
delay
in
the
performance
of
this
Contract.
It
is,
therefore,
agreed
that
Contractor
will
pay
as
liquidated
damages
to
the
City
the
following
sum
of
$500.00
per
Calendar
Day,
for
each
and
every
Calendar
Days
delay
in
finishing
the
Work
in
excess
of
the
number
of
Working
Days
prescribed
above.
If
liquidated
damages
are
not
paid,
as
assessed
by
the
City,
the
City
may
deduct
the
amount
thereof
from
any
money
due
or
that
may
become
due
the
Contractor
under
this
Contract
in
addition
to
any
other
remedy
available
to
City
.
By
executing
this
Contract,
Contractor
agrees
that
the
amount
of
liquidated
damages
is
reasonable
and
shall
not
constitute
a
penalty.
8. In
accordance
with
State
of
California
Senate
Bill
No.
854,
Contractor
will
maintain
and
will
require
all
subcontractors
to
maintain
valid
and
current
Department
of
Industrial
Relations
(DIR)
Public
Works
Contractor
registration
during
the
term
of
this
project.
Contractor
shall
notify
the
City
in
writing
immediately,
and
in
no
case
more
than
twenty-four
(24)
hours,
after
receiving
any
information
that
Contractor's
or
any
of
its
Subcontractor's
DIR
registration
status
has
been
suspended,
revoked,
expired,
or
otherwise
changed.
9. Contractor
will
pay,
and
will
require
all
subcontractors
to
pay,
all
employees
on
said
Contract
a salary
or
wage
at
least
equal
to
the
prevailing
salary
or
wage
established
for
such
work
as
set
forth
in
the
wage
determinations
and
wage
standards
applicable
to
this
work,
a
copy
of
which
is
on
file
in
the
office
of
the
City
Clerk
of
the
City
of
Poway
.
Federal
prevailing
wage
rates
apply
for
federally
funded
projects.
Travel
and
subsistence
pay
shall
be
paid
in
accordance
with
Labor
Code§
1773.1.
10. Contractor
shall
be
subject
to
the
penalties
in
accordance
with
Labor
Code
of
§
1775
for
each
worker
paid
(either
by
Contractor
or by
any
subcontractors
under
Contractor)
less
than
the
prevailing
rate
described
above
on
the
work
provided
for
in
this
Contract.
11. Contractor
and
subcontractors
shall
comply
with
Labor
Code
§
1810
and
§
1811
which
stipulates
that
eight
hours
labor
constitutes
a
legal
day's
work,
and
§
1812
which
stipulates
that
the
Contractor
and
subcontractors
shall
keep
an
accurate
record
showing
the
name
of
and
actual
hours
worked
each
calendar
day
and
each
4 of
11 February 20, 2024, Item #2
calendar
week
by
each
worker
employed
by
them
in
connection
with
the
work
performed
under
the
terms
of
the
Contract.
Failure
to
comply
with
these
sections
of
the
Labor
Code
will
subject
the
Contractor
to
penalty
and
forfeiture
provisions
of
the
Labor
Code§
1813.
12. Contractor
will
comply
with
the
provisions
of
Labor
Code§
1777.5
pertaining
to
the
employment
of
apprentices
to
the
extent
applicable
to
this
Contract.
13 .
Contractor,
by
executing
this
Contract,
hereby
certifies:
"I
am
aware
of
and
will
comply
with
the
Labor
Code
§
3700
by
securing
payment
for
and
maintaining
in
full
force
and
effect
for
the
duration
of
the
contract,
complete
Workers'
Compensation
Insurance,
and
shall
furnish
a
Certificate
of
Insurance
to
the
City
before
execution
of
the
Contract.
The
City,
its
officers,
or
employees,
will
not
be
responsible
for
any
claims
in
law or
equity
occasioned
by
failure
of
the
Contractor
to
comply
with
this
paragraph."
Contractor
further
agrees
to
require
all
subcontractors
to
carry
Workers'
Compensation
Insurance
as
required
by
the
Labor
Code
of
the
State
of
California.
'
14. Contractor
shall,
concurrent
with
the
execution
of
this
Contract,
furnish two
bonds
approved
by
the
City,
one
in
the
amount
of
One
Hundred
Percent
(100%)
of
the
Contract
Price,
to
guarantee
the
faithful
performance
of
the
work
("Performance
Bond"),
and
one
in
the
amount
of
One
Hundred
Percent
(100%)
of
the
Contract
Price
to
guarantee
payment
of
all
claims
for
labor
and
materials
furnished
("Payment
Bond").
This
Contract
shall
not
become
effective
until
such
bonds
are
supplied
to
and
approved
by
the
City.
15 .
a.
Contractor
shall
procure
and
maintain
at
its
own
expense,
until
completion
of
5 of
11 performance,
commercial general
liability
insurance
of
not
less
than
One
Million
Dollars
($1,000,000)
combined
single
limit
per
occurrence,
and
Two
Million
Dollars
($2,000,000)
in
the
aggregate,
for
bodily
injury,
personal
injury,
death,
loss
or
damage
resulting
from
the
wrongful
or
negligent
acts
by
the
Contractor
or
its
officers,
employees,
servants,
volunteers
and
agents
and
independent
contractors
.
Contractor
shall
provide
insurance
on
an
occurrence,
not
claims-made
basis.
Contractor
acknowledges
and
agrees
that,
for
purposes
of
clarification
with
the
intention
of
avoiding
gaps
in
coverage
with
any
umbrella
or
excess
insurance,
personal
and
advertising
injury
coverage
shall
be
triggered
by
an
"offense"
while
bodily
injury
and
property
damage
coverage
shall
be
triggered
by
an
"occurrence"
during
the
policy
period.
b.
Contractor
shall
further
procure
and
maintain
at
its
own
expense,
until
completion
of
performance,
commercial
vehicle
liability
insurance
covering
personal
injury
and
property
damage,
of
not
less
than
One
Million
Dollars
($1,000,000)
combined
single
limit
per
occurrence,
and
Two
Million
Dollars
($2,000,000)
in
the
aggregate,
covering
any
vehicle
utilized
by
Contractor
or
its
officers,
employees,
February 20, 2024, Item #2
6 of
11 servants,
volunteers
and
agents
and
independent
contractors
in
performing
the
services
required
by
this
Agreement.
c.
Contractor
shall
further
procure
and
maintain
at
its
expense,
until
completion
of
performance,
workers'
compensation
insurance
providing
coverage
as
required
by
the
California
State
Workers'
Compensation
Law
. If
any
class
of
employees
employed
by
the
Contractor
pursuant
to
this
Agreement
is
not
protected
by
the
California
State
Workers'
Compensation
Law
, Contractor
shall
provide
adequate
insurance
for
the
protection
of
such
employees
to
the
satisfaction
of
the
City
. This
provision
shall
not
apply
if Contractor
has
no
employees
performing
work
under
this
Agreement.
Contractor
agrees
to
waive
its
statutory
immunity
under
any
worker's
compensation
or
similar
statute
, as
respecting
the
City,
and
to
require
any
and
all
subcontractors
and
any
other
person
or
entity
involved
with
the
Project
to
do
the
same. Worker's
Compensation
Insurance:
o
Contractor
has
no
employees
and
is
exempt
from
workers'
compensation
requirements
.
o
Contractor
carries
workers'
compensation
insurance
for
all
employees.
d.
All
policies
required
by
this
section
shall
be
secured
from
insurers
authorized
to
do
business
in
the
State
of
California
with
an
"A"
policyholder's
rating
or
better
and
a
financial
rating
of
at
least
Class
VII,
in
accordance
with
the
current
Best's
Ratings. e.
Contractor
agrees
to
require
that
all
parties,
including
but
not
limited
to
subcontractors,
architects,
engineers
or
others
with
whom
Contractor
enters
into
contracts
or
whom
Contractor
hires
or retains
pursuant
to
or
in
any
way
related
to
the performance
of
this
Agreement,
provide
the
insurance
coverage
required
herein,
at
minimum,
and,
except
for
worker's
compensation
coverage
, name
as
additional
insureds
the
parties
to
this
Agreement.
Contractor
agrees
to
monitor
and
review
all
such
coverage
and
assumes
all
responsibility
for
ensuring
that
such
coverage
is
provided
in
conformity
with
the
requirements
of
this
Section.
f.
In
the
event
this
Agreement
is
terminated
for
any
reason
prior
to
the
completion
of
all
obligations
and
requirements
of
this
Agreement
, Contractor
agrees
to
maintain
all
coverages
required
herein
until
the City
provides
written
authorization
to
terminate
the
coverages
following
the
City's
review
and
determination
that
all
liability
posed
under
this
Agreement
as
to
the
party
providing
insurance
has
been
eliminated. g.
Contractor
agrees
and
acknowledges
that
if
it
fails
to
obtain
all
of
the
insurance
required
in
this
Agreement
in
accordance
with
the
requirements
herein,
or
to
obtain
and
ensure
that
the
coverage
required
herein
is
maintained
by
any
subcontractors
or
others
involved
in
any
way
with
the
Project,
Contractor
shall
be
responsible
for
any
losses
, claims,
suits,
damages,
defense
obligations,
or
liability
of
any
kind
or
nature
attributable
to
the
City
, and/or
its
officers,
employees
, servants,
February 20, 2024, Item #2
volunteers,
agents
and
independent
contractors,
that
result
from
such
failure
by
Contractor.
16. a.
Contractor
shall
provide
certificates
of
insurance
with
original
endorsements
to
the
City
as
evidence
of
the
insurance
coverage
required
herein.
Certificates
of
such
insurance
shall
be
filed
with
the
City
on
or
before
commencement
of
performance
of
this
Agreement.
Current
certification
of
insurance
shall
be
kept
on
file
with
the
City
at
all
times
until
completion
of
performance
and
acceptance
by
the
City. b.
Notwithstanding
any
inconsistent
statement
in
any
required
insurance
policies
or
any
subsequent
endorsements
attached
thereto,
the
commercial
general
liability
and
commercial
vehicle
liability
policies
shall
bear
endorsements
whereby
it
is
provided that
the
City,
and
its
officers,
employees,
servants,
volunteers,
agents
and
independent
contractors
are
named
as
additional insureds.
Additional
insureds
shall
be
entitled
to
the
full
benefit
of
all
insurance
policies
in
the
same
manner
and
to
the
same
extent
as
any
other
insureds
and
there
shall
be
no
limitation
to
the
benefits
conferred
upon
them
other
than
policy
limits
to
coverages
.
c.
Contractor
shall
require
the
carriers
of
all
required
insurance
policies
to
waive
all
rights
of
subrogation
against
the
City,
and
its
officers,
employees,
servants,
volunteers,
agents
and
independent
contractors
.
d.
Each
policy
required
herein
must
be
endorsed
to
provide
that
the
policy
shall
not
be
cancelled
in
coverage
or
limits
(except
by
paid
claims)
unless
the
insurer
has
provided the
City
with
30 days
prior
written
notice
of
cancellation
. Contractor
agrees
to
provide
the
City
with
30 days
written
notice prior
to
any
non-renewal or
reduction
in
coverage
or limits.
e.
All
insurance
policies
required
to
be
provided
by
Contractor
or
any
other
party
must
be
endorsed
to
provide
that
the
policies
shall
apply
on
a
primary
and
noncontributing
basis
in
relation
to
any
insurance
or
self-insurance,
primary
or
excess,
maintained
or
available
to
the
City,
and
its
officers,
employees,
servants,
volunteers,
agents
and
independent
contractors.
17. a.
Contractor
shall
defend,
indemnify
and
hold
harmless
the
City,
its
officers,
7 of
11 officials,
agents,
employees
and
volunteers
from
and
against
any
and
all
claims,
demands,
actions,
losses,
damage,
injuries,
and
liability,
direct
or
indirect
(including
any
and
all
costs
and
expenses
in
connection
therewith)
to
the
extent
actually
caused
by
the
negligence
of
Contractor,
Contractor's
employees,
subcontractors
or
independent
contractors
except
for
any
such
claim
arising
out
of
the
negligence
or
willful
misconduct
of
the
City,
or its
officers,
agents,
employees
or
volunteers
.
b.
The
City
does
not,
and
shall
not,
waive
any
rights
that
it
may
have
against
Contractor
under
this
Section
because
of
the
acceptance
by
the
City,
or
the
deposit
with
the
City
,
of
any
insurance
policy
or
certificate
required
pursuant
to
this
Agreement.
The
hold
harmless,
indemnification
and
duty
to
defend
provisions
of
this
Section
shall
apply
regardless
of
whether
or
not
said
insurance
policies
are
February 20, 2024, Item #2
determined to be applicable to the claim, demand, action, damage, liability, loss, cost or expense described herein.
18. Any amendments to any of the Contract Documents, including but not limited to Contract Change Orders, must be in writing executed by the Contractor and the City. Any time an approval, time extension, or consent of the City is required under the Contract Documents, such approval, extension, or consent must be in writing in order to be effective.
19. The Contract Documents contain all of the agreements and understandings of the parties and all previous understandings, negotiations, and contracts are integrated into and superseded by this Contract.
20. In the event that any one or more of the phrases, sentences, clauses, paragraphs, or sections contained in this Contract shall be declared invalid or unenforceable by a valid judgment or decree of a court of competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining phrases, sentences, clauses, paragraphs, or sections of this Contract which are hereby declared as severable and shall be interpreted to carry out the intent of the parties hereunder.
21. The persons executing this Contract on behalf of the parties hereto warrant that they are duly authorized to execute this Contract on behalf of said parties and that, by so executing this Contract, the parties hereto are formally bound to the provisions of this Contract.
22. This Contract shall be binding upon and shall inure to the benefit of the parties hereto and their respective heirs, personal representatives, successors, and assigns.
23. In performing its obligations and duties under this Contract, each party shall comply with all applicable local, state, and federal laws, regulations, rules, standards and ordinances.
24. This Contract may be executed by the parties in counterparts, which counterparts shall be construed together and have the same effect as if all of the parties had executed the same instrument.
25. After completion of the work contemplated by this Contract, Contractor shall file with the City Manager an affidavit stating that all workers and persons employed, all firms supplying materials, and all subcontractors upon the project have been paid in full, and that there are no claims outstanding against the project for either labor or materials, except certain items, if any, to be set forth in an affidavit covering disputed claims or items in connection with a Stop Notice that has been filed under the provision of the laws of the State of California.
26. All work shall be subject to inspection and testing by City and its authorized representatives during manufacture and construction and all other times and places, including, without limitation, the plans of Contractor and any of its suppliers.
Contractor shall provide all reasonable facilities and assistance for the safety and convenience of inspectors. All inspections and tests shall be performed in such 8 of 11
February 20, 2024, Item #2
manner
as
to
not
unduly
delay
the
work.
The
Work
shall
be
subject
to
final
inspection
and
acceptance
notwithstanding
any
payments
or
other
prior
inspections.
Such
final
inspection
shall
be
made
within
a reasonable
time
after
completion
of
the
work.
27. Whenever
Contractor
has
knowledge
that
any
actual
or
potential
labor
dispute
is
delaying
or
threatens
to
delay
the
timely
performance
of
the
Contract,
Contractor
shall
immediately
give
notice
thereof,
including
all
relevant
information
with
respect
thereto,
to
City.
28. Contractor
agrees
to
contact
the
appropriate
regional
notification
center
in
accordance
with
Government
Code
Section
4216.2.
29. Contractor
shall
submit
its
detailed
plan
for
worker
protection
during
the
excavation
of
trenches
required
by
the
scope
of
the
work
in
accordance
with
Labor
Code
Section
6705.
30. a.
Contractor
shall,
without
disturbing
the
condition,
notify
City,
in
writing,
as
9 of
11 soon
as
Contractor,
or
any
of
Contractor's
subcontractors,
agents,
or
employees
have
knowledge
and
reporting
is
possible,
of
the
discovery
of
any
of
the
following
conditions
: i.
The
presence
of
any
material
that
Contractor
believes
is
hazardous
waste,
as
defined
in
Section
25117
of
the
Health
and
Safety
Code;
ii.
Subsurface
or
latent
physical
conditions
at
the
site differing
from
those
indicated
in
the
specifications;
or
iii.
Unknown
physical
conditions
at
the
site
of
any
unusual
nature,
different
materially
for
those
ordinarily
encountered
and
generally
recognized
as
inherent
in
work
of
the
character
provided
for
in
this
Contract.
b.
Pending
a determination
by
City
of
appropriate
action
to
be
taken,
Contractor
shall
provide
security
measures
(e.g.,
fences)
adequate
to
prevent
the
hazardous
waste
or
physical
conditions
from
causing
bodily
injury
to
any
person.
c.
City shall
promptly
investigate
the
reported
conditions
. If City,
through
and
in
the
exercise
of
its
sole
discretion,
determines
that
the
conditions
do
materially
differ
or
do
involve
hazardous
waste,
and
will
cause
a
decrease
or
increase
in
Contractor's
cost
of,
or
time
required
for,
performance
of
any
part
of
the
work,
then
City
shall
issue
a
change
order.
d.
In
the
event
of
a
dispute
between
City
and
Contractor
as
to
whether
the
conditions
materially
differ,
or
involve
hazardous
waste,
or
cause
a
decrease
or
increase
in
Contractor's
cost
of,
or
time
required
for,
performance
of
any
part
of
the
work,
Contractor
shall
not
be
excused
from
any
scheduled
completion
date,
and
shall
proceed
with
all
work
to
be
performed
under
the
contract.
Contractor
shall
retain
any
and
all
rights
that
pertain
to
the
resolution
of
disputes
and
protests
between
the
parties.
February 20, 2024, Item #2
31. This Contract is to be governed by the laws of the State of California.
32. All work shall be guaranteed for a period of one (1) year from the date of acceptance by the City. Contractor shall promptly make all needed repairs arising out of defective materials, workmanship, and equipment.
City is hereby authorized to make such repairs if within ten (10) days after giving written notice to Contractor, or its agent, Contractor should fail to make or undertake with due diligence the aforesaid repairs; provided, however, that in case of an emergency, where, in the opinion of City, delay would cause serious loss or damage, repairs may be made without notice being sent to Contractor, and Contractor shall pay the costs thereof. (Remainder of page intentionally left blank)
10 of 11
February 20, 2024, Item #2
IN WITNESS WHEREOF, the said Contractor and the City Manager, City Clerk and City Attorney have caused the names of said parties to be affixed hereto, the day and year first above written.
Contractor's Name:
Print Name of Construction Company
By: -------------
Signature
Print Name
Contractor information:
Address for Notices and Payments
Telephone Number: ______ _
Email:
CITY OF POWAY
a Municipal Corporation
Chris Hazeltine, City Manager
ATTEST:
Carrie Gallagher, CMC, City Clerk
APPROVED AS TO FORM:
RUTAN & TUCKER, LLP
Alan Fenstermacher, City Attorney
11 of 11