May 20, 2025, Item #5
AGENDA RE PO RT City of Poway
DATE: May 20, 2025
TO: Honorable Mayor and Members of the City Council
FROM: Julie Procopio, Director of Development Service~
CONTACTS: Cassandra Seaboch, Assistant Engineer
(858) 668-4625 or [email protected]
Jeff Beers, Capital Projects Manager
(858) 668-4624 or [email protected]
CITY COUNCIL
SUBJECT: Award of Contract to Quality Construction & Engineering Inc. for the FY 2024-2025 Street Overlay Project; Bid No. 25-01 O
Summary:
This action will award a construction contract for the FY 2024-25 Street Overlay project. The project includes asphalt overlay and/or cold milling and patching on arterial and residential streets in Zone 8.
The City is divided into eight (8) street maintenance zones. The City completes maintenance within each zone in a rotational yearly street maintenance program. The FY 2024-25 Street Overlay project will occur in Zone 8.
Recommended Action:
It is recommended the City Council:
1) Award the contract for the FY 2024-25 Street Overlay project to Quality Construction & Engineering Inc., in the amount of $2,628,512.00 and authorize the City Manager to execute the contract (Attachment A);
2) Appropriate additional funds in the amount of $563,459.48 from the Gas Tax Fund (2110) for construction of the FY 2024-25 Street Overlay Zone 8 project (ST031); and 3) Make a determination the project is Categorically Exempt from the California Environmental Quality Act (CEQA).
Discussion:
The scope of work includes the asphalt overlay of five (5) residential streets, Casa Court, Evalyn Place, lpai Waaypuk Trail, Rancho Caballo Road, and Rick Street within Street Maintenance Zone 8 (Attachment B). Asphalt patch repairs will be completed on residential streets and arterial streets including Poway Road from west city limits to Community Road, Pomerado Road from Poway Road to south city limit, Scripps Poway Parkway from west city limits to Pomerado Road and Ted Williams Parkway from west city limits to Pomerado Road. Americans with Disabilities Act (ADA) pedestrian 1 of 12
May 20, 2025, Item #5
ramp removal and replacement will be completed on overlayed residential streets and arterial roads.
This work is being coordinated in Zone 8 with the FY 2025-26 Annual Street Maintenance and FY 2025- 26 Citywide Striping projects. Construction is anticipated to start this June and continue through early fall. Nighttime and weekend work will be required during the project to minimize disruptions to traffic.
Bids were opened on April 16, 2025. The following bids were received:
Company Total Bid Amount
Quality Construction & Engineering Inc. $2,628,512.00
Calmex Engineering, Inc $2,987,814.00
Frank and Son Paving Inc $ 3,252,020.54
Palm Engineering Construction $ 3,543,166.82
R.J. Noble Company $3,903,357.00
TC Construction Company, Inc. $ 4,277,038.00
The apparent low bid of $2,628,512.00 submitted by Quality Construction & Engineering Inc. is responsive to, and meets the requirements of, the bid specifications. The contract time for this project is 60 working days with an Engineer's Estimate of $2,107,000. The Engineer's Estimate is based on previous years' street overlay project costs and current market values of construction costs. The higher-than-expected bids for this project can be attributed, in part, to the volatile market conditions, where fluctuating material prices and labor costs have driven up the overall expenses.
Environmental Review:
The proposed asphalt/concrete pavement rehabilitation of existing City streets with the FY 2024-25 Street Overlay project is Categorically Exempt from the California Environmental Quality Act (CEQA) as a Class 1 Categorical Exemption, pursuant to Section 15301 (c) of the CEQA Guidelines, in that the project involves maintenance of existing streets with no expansion of use.
Fiscal Impact:
There is $2,350,102.52 available in the FY 2024-25 Street Overlay project account (ST031 ), with project funds coming from the Trans Net Fund 2230. These funds represent a portion of Poway's share of the voter approved regional ½ cent sales tax measure implemented by the San Diego Association of Governments. With the recommended appropriation in the amount of $563,459.48 from the Gas Tax Fund (2110) included in this report, there will be sufficient funds in the project account to cover the construction costs of the project. The budget of $2,913,562.00 will include the cost for the construction contract, 10% construction contingency allowance and materials testing services.
Attachments:
A. Construction Contract
B. Zone 8 Street Overlay Map
Reviewed/Approved By:
Wendy Kaserman
Assistant City Manager
2 of 12
Reviewed By:
Alan Fenstermacher
City Attorney
Approved By:
Ch~~
City Manager
May 20, 2025, Item #5
SECTION
8 CONSTRUCTION
CONTRACT
CITY
OF
POWAY
FY
2024-25
Street
Overlay
Zone
8 This
Contract
made
and
entered
into
this
21st
day
of
May
2025,
by
and
between
City
of
Poway,
a
municipal corporation
of
the
State
of
California,
hereinafter
referred
to
as
"City"
and
Quality
Construction
&
Engineering
Inc.,
hereinafter
referred
to
as
"Contractor."
The
City
and
the
Contractor,
for
the
consideration
hereinafter
named,
mutually
agree
as
follows: 1.
The
complete
Contract
includes
all
of
the
Contract
Documents,
which
are
incorporated
herein
by
this
reference,
and
include:
a.
This
Contract
b.
Contract
Addenda
c.
Contract
Change
Orders
d.
Instructions
to
Bidders,
Proposal
Requirements
and
Conditions
e.
Contract
Specifications
f.
Contract
Plans
g.
General
Condition
h.
Special
Conditions
i.
Standard
Specification
for
Public
Works,
most
current
edition
2. The
Contract
Documents
are
complementary,
and
that
which
is
required
by
one
shall
be
as
binding
as
if required
by
all.
3. Contractor
shall
provide
and
furnish
all
labor,
materials,
necessary
tools,
expendable
equipment,
and
all
utility
and
transportation
services
required
for
the
following
work
of
improvement:
The
FY
2024-2025
Street
Overlay
Zone
8 project
consists
of
asphalt
overlay
of
residential
streets
and
asphalt
cold
milling
and
patching
on
arterial
and
residential
streets
. Pedestrian
ramp
removal
and
replacement
on
residential
and
arterial
streets
are
also
required.
4. Contractor
agrees
to
perform
all
the
said
work
and
furnish
all
the
said
materials
at
their
own
cost
and
expense
that
are
necessary
to
construct
and
complete
in
strict
3 of
12 ATTACHMENT
A
May 20, 2025, Item #5
conformance
with
Contract
Documents
and
to
the
satisfaction
of
the
City
Engineer,
the
work
hereinafter set
forth
in
accordance
with
the
Contract
adopted
by
the
City
Council.
5. City agrees
to
pay
and
Contractor
agrees
to
accept
in
full
payment
for
performance
of
this
work
of
improvement
as
described,
the
stipulated
sum
of
$2,628,512
.00
the
"Contract
Price
."
City
agrees
to
make
progress
payments
and
final
payment
in
accordance
with
the
method
set
forth
in
the
Special
Provisions
.
6. Contractor
agrees
to
commence
construction
of
the
work
provided
for
herein
within
Fifteen
(15)
Calendar
Days
after
the
date
specified
in
the
Notice
to
Proceed,
and
to
continue
diligently
in
strict
conformance
with
Contract
Documents
and
without
interruption,
and
to
complete
the
construction
thereof
within
60 Working
Days
after
the
date
specified
in
the
Notice
to
Proceed.
7. Time
is
of
the
essence
of
this
Contract,
and
it
is
agreed
that
it
would
be
impracticable
or
extremely
difficult
to
ascertain
the
extent
of
actual
loss
or
damage
which
the
City
will
sustain
by
reason
of
any
delay
in
the
performance
of
this
Contract.
It
is,
therefore,
agreed
that
Contractor
will
pay
as
liquidated
damages
to
the
City
the
following
sum
of
$500.00
per
Calendar
Day,
for
each
and
every
Calendar
Days
delay
in
finishing
the
Work
in
excess
of
the
number
of
Working
Days
prescribed
above.
If
liquidated
damages
are
not
paid,
as
assessed
by
the
City
, the
City
may
deduct
the
amount
thereof
from
any
money
due
or
that
may
become
due
the
Contractor
under
this
Contract
in
addition
to
any
other
remedy
available
to
City.
By
executing
this
Contract,
Contractor
agrees
that
the
amount
of
liquidated
damages
is
reasonable
and
shall
not
constitute
a
penalty.
8. In
accordance
with
State
of
California
Senate
Bill
No.
854,
Contractor
will
maintain
and
will
require
all
subcontractors
to
maintain
valid
and
current
Department
of
Industrial
Relations
(DIR)
Public
Works Contractor
registration
during
the
term
of
this
project.
Contractor
shall
notify
the
City
in
writing
immediately,
and
in
no
case
more
than
twenty-four
(24)
hours,
after
receiving
any
information
that
Contractor's
or
any
of
its
Subcontractor's
DIR
registration
status
has
been
suspended,
revoked,
expired,
or
otherwise
changed.
9. Contractor
will
pay,
and
will
require
all
subcontractors
to
pay,
all
employees
on
said
Contract
a salary
or
wage
at
least
equal
to
the
prevailing
salary
or
wage
established
for
such
work
as
set
forth
in
the
wage
determinations
and
wage
standards
applicable
to
this
work,
a
copy
of
which
is
on
file
in
the
office
of
the
City
Clerk
of
the
City
of
Poway.
Federal
prevailing
wage
rates
apply
for
federally
funded
projects.
Travel
and
subsistence
pay
shall
be
paid
in
accordance
with
Labor
Code§
1773.1.
10. Contractor
shall
be
subject
to
the
penalties
in
accordance
with
Labor
Code
of
§
1775
for
each
worker
paid
(either
by
Contractor
or
by
any
subcontractors
under
Contractor)
less
than
the
prevailing
rate
described
above
on
the
work
provided
for
in
this
Contract.
4 of
12 May 20, 2025, Item #5
11. Contractor
and
subcontractors
shall
comply
with
Labor
Code
§
1810
and
§
1811
which
stipulates
that
eight
hours
labor
constitutes
a
legal
day's
work,
and§
1812
which
stipulates
that
the
Contractor
and
subcontractors
shall
keep
an
accurate
record
showing
the
name
of
and
actual
hours
worked
each
calendar
day
and
each
calendar
week
by
each
worker
employed
by
them
in
connection
with
the
work
performed
under
the
terms
of
the
Contract.
Failure
to
comply
with
these
sections
of
the
Labor
Code
will
subject
the
Contractor
to
penalty
and
forfeiture
provisions
of
the
Labor
Code§
1813.
12 .
Contractor
will
comply
with
the
provisions
of
Labor
Code§
1777.5
pertaining
to
the
employment
of
apprentices
to
the
extent
applicable
to
this
Contract.
13. Contractor,
by
executing
this
Contract,
hereby
certifies:
"I
am
aware
of
and
will
comply
with
the
Labor
Code
§
3700
by
securing
payment
for
and
maintaining
in
full
force
and
effect
for
the
duration
of
the contract,
complete
Workers'
Compensation
Insurance,
and
shall
furnish
a
Certificate
of
Insurance
to
the
City
before execution
of
the
Contract.
The
City,
its
officers,
or
employees,
will
not
be
responsible
for
any
claims
in
law
or
equity
occasioned
by
failure
of
the
Contractor
to
comply
with
this
paragraph
."
Contractor
further
agrees
to
require
all
subcontractors
to
carry
Workers'
Compensation
Insurance
as
required
by
the
Labor
Code
of
the
State
of
California.
14. Contractor
shall,
concurrent with
the
execution
of
this
Contract,
furnish
two
bonds
approved
by
the
City,
one
in
the
amount
of
One
Hundred
Percent
(100%)
of
the
Contract
Price,
to
guarantee
the
faithful
performance
of
the
work
("Performance
Bond"),
and
one
in
the
amount
of
One
Hundred
Percent
(100%)
of
the
Contract
Price
to
guarantee
payment
of
all
claims
for
labor
and
materials
furnished
("Payment
Bond").
This
Contract shall
not
become
effective
until
such
bonds
are
supplied
to
and
approved
by
the
City.
15. a.
Contractor
shall
procure
and
maintain
at
its
own
expense,
until
completion
of
5 of
12 performance,
commercial
general
liability
insurance
of
not
less
than
One
Million
Dollars
($1,000,000)
combined
single
limit
per
occurrence,
and
Two
Million
Dollars
($2,000,000)
in
the
aggregate,
for
bodily
injury,
personal
injury,
death,
loss
or
damage
resulting
from
the
wrongful
or
negligent
acts
by
the
Contractor
or
its
officers,
employees,
servants,
volunteers
and
agents
and
independent
contractors.
Contractor
shall
provide
insurance
on
an
occurrence,
not
claims-made
basis.
Contractor
acknowledges
and
agrees
that,
for
purposes
of
clarification
with
the
intention
of
avoiding
gaps
in
coverage
with
any
umbrella
or
excess
insurance,
personal
and
advertising
injury
coverage
shall
be
triggered
by
an
"offense"
while
bodily
injury
and
property
damage
coverage
shall
be
triggered
by
an
"occurrence"
during
the
policy
period
.
b.
Contractor
shall
further
procure
and
maintain
at
its own
expense,
until
completion
of
performance,
commercial
vehicle
liability
insurance
covering
personal
May 20, 2025, Item #5
6 of 12
injury and property damage, of not less than One Million Dollars ($1,000,000) combined single limit per occurrence, and Two Million Dollars ($2,000,000) in the aggregate, covering any vehicle utilized by Contractor or its officers, employees, servants, volunteers and agents and independent contractors in performing the services required by this Agreement.
c. Contractor shall further procure and maintain at its expense, until completion of performance, workers' compensation insurance providing coverage as required by the California State Workers' Compensation Law. If any class of employees employed by the Contractor pursuant to this Agreement is not protected by the California State Workers' Compensation Law, Contractor shall provide adequate insurance for the protection of such employees to the satisfaction of the City. This provision shall not apply if Contractor has no employees performing work under this Agreement. Contractor agrees to waive its statutory immunity under any worker's compensation or similar statute, as respecting the City, and to require any and all subcontractors and any other person or entity involved with the Project to do the same.
Worker's Compensation Insurance:
o Contractor has no employees and is exempt from workers' compensation requirements.
o Contractor carries workers' compensation insurance for all employees. d. All policies required by this section shall be secured from insurers authorized to do business in the State of California with an "A" policyholder's rating or better and a financial rating of at least Class VII, in accordance with the current Best's Ratings.
e. Contractor agrees to require that all parties, including but not limited to subcontractors, architects, engineers or others with whom Contractor enters into contracts or whom Contractor hires or retains pursuant to or in any way related to the performance of this Agreement, provide the insurance coverage required herein, at minimum, and, except for worker's compensation coverage, name as additional insureds the parties to this Agreement. Contractor agrees to monitor and review all such coverage and assumes all responsibility for ensuring that such coverage is provided in conformity with the requirements of this Section. f. In the event this Agreement is terminated for any reason prior to the completion of all obligations and requirements of this Agreement, Contractor agrees to maintain all coverages required herein until the City provides written authorization to terminate the coverages following the City's review and determination that all liability posed under this Agreement as to the party providing insurance has been eliminated.
g. Contractor agrees and acknowledges that if it fails to obtain all of the insurance required in this Agreement in accordance with the requirements herein, or to obtain and ensure that the coverage required herein is maintained by any subcontractors or others involved in any way with the Project, Contractor shall be May 20, 2025, Item #5
responsible
for
any
losses,
claims,
suits,
damages,
defense
obligations,
or
liability
of
any
kind
or
nature
attributable
to
the
City,
and/or
its
officers,
employees,
servants,
volunteers,
agents
and
independent
contractors,
that
result
from
such
failure
by
Contractor.
16. a.
Contractor
shall
provide
certificates
of
insurance
with
original
endorsements
to
the
City
as
evidence
of
the
insurance
coverage
required
herein.
Certificates
of
such
insurance
shall
be
filed
with
the
City
on
or
before
commencement
of
performance
of
this
Agreement.
Current
certification
of
insurance
shall
be
kept
on
file
with
the
City
at
all
times
until
completion
of
performance
and
acceptance
by
the
City. b.
Notwithstanding
any
inconsistent
statement
in
any
required
insurance
policies
or
any
subsequent
endorsements
attached
thereto,
the
commercial
general
liability
and
commercial
vehicle
liability
policies
shall
bear
endorsements
whereby
it
is
provided
that
the
City,
and
its
officers,
employees,
servants,
volunteers,
agents
and
independent
contractors
are
named
as
additional
insureds.
Additional
insureds
shall
be
entitled
to
the
full
benefit
of
all
insLJrance
policies
in
the
same
manner
and
to
the
same
extent
as
any
other
insureds
and
there
shall
be
no
limitation
to
the
benefits
conferred
upon
them
other
than
policy
limits
to
coverages.
c.
Contractor
shall
require
the
carriers
of
all
required
insurance
policies
to
waive
all
rights
of
subrogation
against
the
City,
and
its
officers,
employees,
servants,
volunteers,
agents
and
independent
contractors.
d.
Each
policy
required
herein
must
be
endorsed
to
provide
that
the
policy
shall
not
be
cancelled
in
coverage
or
limits
(except
by paid
claims)
unless
the
insurer
has
provided
the
City
with
30 days
prior
written
notice
of
cancellation.
Contractor
agrees
to
provide
the
City
with
30 days
written
notice
prior
to
any
non-renewal
or
reduction
in
coverage
or limits.
e.
All
insurance
policies
required
to
be
provided
by
Contractor
or
any
other
party
must
be
endorsed
to
provide
that
the
policies
shall
apply
on
a
primary
and
noncontributing
basis
in
relation
to
any
insurance
or
self-insurance,
primary
or
excess,
maintained
or
available
to
the
City,
and
its
officers,
employees,
servants,
volunteers,
agents
and
independent
contractors.
17 .
a.
Contractor
shall
defend,
indemnify
and
hold
harmless
the
City,
its
officers,
7 of
12 officials,
agents,
employees
and
volunteers
from
and
against
any
and
all
claims,
demands,
actions,
losses,
damage,
injuries,
and
liability,
direct
or
indirect
(including
any
and
all
costs
and
expenses
in
connection
therewith)
to
the
extent
actually
caused
by
the
negligence
of
Contractor,
Contractor's
employees,
subcontractors
or
independent
contractors
except
for
any
such
claim
arising
out
of
the
negligence
or
willful
misconduct
of
the
City,
or
its
officers,
agents,
employees
or
volunteers.
b.
The
City
does
not,
and
shall
not,
waive
any
rights
that
it may
have
against
Contractor
under
this
Section
because
of
the
acceptance
by
the
City,
or
the
deposit
with
the
City,
of
any
insurance
policy
or
certificate
required
pursuant
to
this
Agreement.
The
hold
harmless,
indemnification
and
duty
to
defend
provisions
of
this
May 20, 2025, Item #5
Section shall apply regardless of whether or not said insurance policies are determined to be applicable to the claim, demand, action, damage, liability, loss, cost or expense described herein.
18. Any amendments to any of the Contract Documents, including but not limited to Contract Change Orders, must be in writing executed by the Contractor and the City. Any time an approval, time extension, or consent of the City is required under the Contract Documents, such approval, extension, or consent must be in writing in order to be effective.
19. The Contract Documents contain all of the agreements and understandings of the parties and all previous understandings, negotiations, and contracts are integrated into and superseded by this Contract.
20. In the event that any one or more of the phrases, sentences, clauses, paragraphs, or sections contained in this Contract shall be declared invalid or unenforceable by a valid judgment or decree of a court of competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining phrases, sentences, clauses, paragraphs, or sections of this Contract which are hereby declared as severable and shall be interpreted to carry out the intent of the parties hereunder.
21. The persons executing this Contract on behalf of the parties hereto warrant that they are duly authorized to execute this Contract on behalf of said parties and that, by so executing this Contract, the parties hereto are formally bound to the provisions of this Contract.
22. This Contract shall be binding upon and shall inure to the benefit of the parties hereto and their respective heirs, personal representatives, successors, and assigns.
23. In performing its obligations and duties under this Contract, each party shall comply with all applicable local, state, and federal laws, regulations, rules, standards and ordinances.
24. This Contract may be executed by the parties in counterparts, which counterparts shall be construed together and have the same effect as if all of the parties had executed the same instrument.
25. After completion of the work contemplated by this Contract, Contractor shall file with the City Manager an affidavit stating that all workers and persons employed, all firms supplying materials, and all subcontractors upon the project have been paid in full, and that there are no claims outstanding against the project for either labor or materials, except certain items, if any, to be set forth in an affidavit covering disputed claims or items in connection with a Stop Notice that has been filed under the provision of the laws of the State of California.
26. All work shall be subject to inspection and testing by City and its authorized representatives during manufacture and construction and all other times and places, including, without limitation, the plans of Contractor and any of its suppliers.
Contractor shall provide all reasonable facilities and assistance for the safety and 8 of 12
May 20, 2025, Item #5
convenience
of
inspectors.
All
inspections
and
tests
shall
be
performed
in
such
manner
as
to
not
unduly
delay
the
work
. The
Work
shall
be
subject
to
final
inspection
and
acceptance
notwithstanding
any
payments
or
other
prior
inspections.
Such
final
inspection
shall
be
made
within
a
reasonable
time
after
completion
of
the
work.
27 .
Whenever
Contractor
has
knowledge
that
any
actual
or
potential
labor
dispute
is
delaying
or
threatens
to
delay
the
timely
performance
of
the
Contract,
Contractor
shall
immediately
give
notice
thereof,
including
all
relevant
information
with
respect
thereto,
to
City.
28. Contractor
agrees
to
contact
the
appropriate
regional
notification
center
in
accordance
with
Government
Code
Section
4216.2.
29. Contractor
shall
submit
its
detailed
plan
for
worker
protection
during
the
excavation
of
trenches
required
by
the
scope
of
the
work
in
accordance
with
Labor
Code
Section
6705.
30. a.
Contractor
shall,
without
disturbing
the
condition,
notify
City,
in
writing,
as
9 of
12 soon
as
Contractor,
or
any
of
Contractor's
subcontractors,
agents,
or
employees
have
knowledge
and
reporting
is
possible,
of
the
discovery
of
any
of
the
following
conditions:
i.
The
presence
of
any
material
that
Contractor
believes
is
hazardous
waste,
as
defined
in
Section
25117
of
the
Health
and
Safety
Code;
ii.
Subsurface
or
latent
physical
conditions
atthe
site
differing
from
those
indicated
in
the
specifications;
or
iii.
Unknown
physical
conditions
at
the
site
of
any
unusual
nature,
different
materially
for
those
ordinarily
encountered
and
generally
recognized
as
inherent
in
work
of
the
character
provided
for
in
this
Contract.
b.
Pending
a determination
by
City
of
appropriate
action
to
be
taken,
Contractor
shall
provide
security
measures
(e.g.,
fences)
adequate
to
prevent
the
hazardous
waste
or
physical
conditions
from
causing
bodily
injury
to
any
person.
c.
City
shall
promptly
investigate
the
reported
conditions.
If City,
through
and
in
the
exercise
of
its
sole discretion,
determines
that
the
conditions
do
materially
differ
or
do
involve
hazardous
waste,
and
will
cause
a
decrease
or
increase
in
Contractor's
cost
of,
or
time
required
for,
performance
of
any
part
of
the
work,
then
City
shall
issue
a
change
order.
d.
In
the
event
of
a
dispute
between
City
and
Contractor
as
to
whether
the
conditions
materially
differ,
or
involve
hazardous
waste,
or
cause
a
decrease
or
increase
in
Contractor
's cost
of,
or
time
required
for,
performance
of
any
part
of
the
work,
Contractor
shall
not
be
excused
from
any
scheduled
completion
date,
and
shall
proceed
with
all
work
to
be
performed
under
the
contract.
Contractor
shall
retain
any
and
all
rights
that
pertain
to
the
resolution
of
disputes
and
protests
between
the
parties.
May 20, 2025, Item #5
31. This
Contract
is
to
be
governed
by
the
laws
of
the
State
of
California.
32 .
All
work
shall
be
guaranteed
for
a period
of
one
(1)
year
from
the
date
of
acceptance
by
the
City.
Contractor
shall
promptly
make
all
needed
repairs
arising
out
of
defective
materials,
workmanship,
and
equipment.
10 of
12 City
is
hereby
authorized
to
make
such
repairs
if within
ten
(10)
days
after
giving
written
notice
to
Contractor,
or
its
agent,
Contractor
should
fail
to
make
or
undertake
with
due
diligence
the
aforesaid
repairs;
provided,
however,
that
in
case
of
an
emergency,
where,
in
the
opinion
of
City,
delay
would
cause
serious
loss
or
damage,
repairs
may
be
made
without
notice
being
sent
to
Contractor,
and
Contractor
shall
pay
the
costs
thereof.
(Remainder
of
page
intentionally
left
blank)
May 20, 2025, Item #5
IN
WITNESS
WHEREOF,
the
said
Contractor
and
the
City
Manager,
City
Clerk
and
City
Attorney
have
caused
the
names
of
said
parties
to
be
affixed
hereto,
the
day
and
year
first
above
written.
Contractor's
Name:
Quality
Construction
&
Engineering
Inc.
Print
Name
of
Construction
Company
By:
----------
Signature
Mohammad
Qahoush Print
Name
Contractor
information:
Address
for
Notices
and
Payments
16870
West
Bernardo
Drive
Suite
400
San
Diego,
CA
92127
Telephone
Number:
858-674-6919x6820
Email:
[email protected]
ATTEST: Carrie
Gallagher,
CMG,
City
Clerk
APPROVED
AS
TO
FORM:
RUTAN
&
TUCKER,
LLP
Alan
Fenstermacher,
City
Attorney
11 of
12 CITY
OF
POWAY
a
Municipal
Corporation
Chris
Hazeltine,
City
Manager
May 20, 2025, Item #5
-
Legend Zone
8 Overlay
--
<all
other
values>
Name \\\\\
Overlay
--■
0%
Mill
&
Fill
•
■
■
1 -10%
Mill
&
Fill
i::.
■11•
■
11-
20%
Mill
&
Fill
--
21 -30%
Mill
&
Fill
--
Other
Treatment
-----
!IIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIF --= --= = = ---- N A
0 6501,300
5,200
■--=::11•-==----=======---
Feet
2,600
3,900
ZONE
8 OVERLAY
PROJECT
MAP
12 of
12 ATTACHMENT
B