Description Amount
Service Request Number: 3742236 Project:
2430 MANHATTAN BEACH BLVD U PED REDONDO BEACH CA
90278
Install - Billing Option: SCE INSTALL - DISCOUNT
415 DIAMOND ST
REDONDO BEACH CA 90277
Telephone: (310)-783-9303
REDONDO BEACH, CITY OF
SCE Contact: Amanda Gayle McEvoy
Invoice Date: 06/21/2024
505 MAPLE AVENUE
TORRANCE CA 90503
Southern California Edison Company
Document # 7590561738
Invoice # 549226
Item # 580879
Design #: 1737268
2271151 - LINE EXTENSION
Product: $1,241.86
Previous Payment $0.00
* For Mixed-Fuel projects, payment and signed contracts MUST be received before July 1, 2024, to keep subsidies (allowances, discount/refund options) and estimated cost pricing, otherwise SCE will reprice the project WITHOUT subsidies.
* Effective July 1, 2024, through December 31, 2024, Mixed-Fuel new construction projects (gas or propane in addition to electricity) will not receive subsidies and will be priced as estimated cost. * Effective January 1, 2025, Mixed-Fuel new construction projects will not receive subsidies and will be priced as actual cost billing.
* Enclosed are two copies of your invoice. Please return one copy of the invoice with your payment to Accounts Receivable in the enclosed return-addressed envelope. The other copy of the invoice is for your records. * All payments must be delivered by mail, an alternate postal method, or one of our electronic payment options.
Walk-in payments are no longer accepted at any SCE location, including Accounts Receivable. * Please complete all applications and/or contracts and return to your planning office, using the enclosed return-addressed envelope.
* For the Refundable and Discount Option appendices, choose only one option. Sign "Has Chosen" on the appropriate option and sign "Has Not Chosen" on the other option. Only sign each form once. Return both forms in the enclosed self-addressed envelope.
* If a street light work order is associated with this project, contracts for that project will be enclosed. * Easement documents will be mailed directly to you from our Right of Way department. Please complete and return them as soon as possible, as we will not be able to proceed with the project without clearance * Call the Edison company at 1-800-655-4555 to make application for electrical service. * An Edison Inspector must approve all underground systems. Please call your designated inspector 48 hours prior to construction to schedule an inspection.
* Final electrical inspection from the local governmental building and safety department must be received before we can energize your service.
* By paying this invoice, customer acknowledges and agrees that if this project is canceled by customer for any reason or customer does not proceed with the project completion. * Any expense incurred by SCE, including, but not limited to, expenses related to engineering, inspection and construction, prior to the project cancellation or completion will be deducted from any applicable refund due to the customer.
* To ensure worker and public safety, please maintain the appropriate clearance distance from utility infrastructure during your construction project to avoid encroachments that may result in serious injury or damage. * If relocation of existing utility infrastructure is pending, please adjust your work around the proposed relocation schedule as appropriate. If you have any questions, please contact the designated SCE representative assigned to your project.
$ 1,241.86
COMMENTS:
TOTAL PROJECT INVOICE AMOUNT:
Description Amount
Service Request Number: 3742236 Project:
2430 MANHATTAN BEACH BLVD U PED REDONDO BEACH CA
90278
Install - Billing Option: SCE INSTALL - DISCOUNT
415 DIAMOND ST
REDONDO BEACH CA 90277
Telephone: (310)-783-9303
REDONDO BEACH, CITY OF
SCE Contact: Amanda Gayle McEvoy
Invoice Date: 06/21/2024
505 MAPLE AVENUE
TORRANCE CA 90503
Southern California Edison Company
Document # 7590561738
Invoice # 549226
Please detach and return payment stub with payment
Payment
Stub
REDONDO BEACH, CITY OF
415 DIAMOND ST
REDONDO BEACH CA 90277
Please pay total amount now due:
$ 1,241.86
Thank you for paying promptly
Make check payable to Southern California Edison
Document # 7590561738
ATTN: Remittance Processing
PO Box 800
Rosemead, CA 91771-001
ADDITIONAL PAYMENT INSTRUCTIONS:
If paying by check, please follow instructions on payment stub JP Morgan Chase Bank
New York, NY
ABA#: 021000021 - Acct#: 323-394434
SCE Taxpayer ID No. 95-1240335
Document #: 7590561738
SCE Contact:
Southern California Edison
Attn: Remittance Processing
G.O. 1 Ground Floor, Room G53
2244 Walnut Grove Ave.
Rosemead, CA 91770
Amanda Gayle McEvoy
Instructions for wire or ACH payments:
*** Failure to properly identify your document number and SCE contact may delay the application of funds and initiation of your project
Special Instructions for overnight delivery methods:
LOC. W.O. A.I. JOB #
APPENDIX A - DISCOUNT OPTION
ELECTRIC LINE EXTENSION AGREEMENT
7/6/2024 12:00:00AM
LINE EXTENSION 2271151
1. SCE RULE 16 COST TO SERVE
(A) SCE RULE 16 COST TO SERVE
(B) LESS APPLICANT ALLOWANCES
(C) EXCESS RULE 16 COST TO SERVE (LINE 5. (A))
(D) EXCESS ALLOWANCES TO (LINE 2.)
SCE COST TO SERVE RULE 15
(E) OVERHEAD 0 FEET X $.00 UNIT COST $.00
(F) UNDERGROUND 0 FEET X $.00 UNIT COST $.00
(G) PROJECT SPECIFIC (IF 2X UNIT COST OR COMPETITIVE BID) (H) TOTAL SCE RULE 15 COST TO SERVE
2. APPLICANT ALLOWANCES (FROM LINE 1. (D)
3. REFUNDABLE:
(A) SCE RULE 15 COST TO SERVE (LINE 1. (H))
(B) PLUS ESTIMATED VALUE OF STRUCTURES
(C) SUBTOTAL (LINE 3. (A) + 3. (B))
(D) LESS ALLOWANCE (LINE 2)
(E) REFUNDABLE AMOUNT (LINE 3. (C) - 3. (D))
(F) PLUS REFUNDABLE ITCC* ON LINE 3. (E)
4. PAYMENT OPTION SELECTED: DISCOUNT HAS CHOSEN: SIGN
(A) NON-REFUNDABLE DISCOUNT OPTION: 50 %
1) 50 % OF LINE 3G:
2) VALUE OF STRUCTURES:
3)
4)
NON -REFUNDABLE PAYMENT:
AMOUNT DUE APPLICANT:
5. OTHER NON-REFUNDABLE ADVANCE & CREDITS
(A) OTHER NON-REFUNDABLE CHARGES
(RULE 16, FLAT RATE, INSPECTION, R/W, ETC.)
(B) ITCC* ON OTHER NON-REFUNDABLE
(C) ITCC* ON APPLICANT FURNISHED FACILITIES.
(D) INSTALLED COST OF SUBSTRUCTURES BY SCE
(E) LESS APPLICANT DESIGN OR REIMBURSABLE CREDITS
(F) TOTAL NON-REFUNDABLE (LINE 5. (A) THRU 5. (D) - 5. (E)) (G) TOTAL CREDITS (LINE 5. (E) - 5. (A) THRU 5. (D))
6. AMOUNT TO BE PAID BY APPLICANT TO SCE
7. AMOUNT TO BE REFUNDED TO APPLICANT UPON FULFILLMENT OF ALL
CONTRACTUAL OBLIGATIONS
HAS NOT CHOSEN: SIGN
* INCOME TAX COMPONENT OF CONTRIBUTION
(G) TOTAL AMOUNT (LINE 3. (E) + 3. (F))
$657.37
$12,327.68
$0.00
$11,670.31
$2,467.48
$2,467.48
$11,670.31
$2,467.48
$275.18
$2,742.66
$11,670.31
$0.00
$0.00
$0.00
$0.00
$275.18
$0.00
$275.18
$906.00
$217.44
$393.60
$0.00
$0.00
$1,517.04
$0.00
$1,241.86
$0.00
Description Amount
Service Request Number: 3742236 Project:
2430 MANHATTAN BEACH BLVD U PED REDONDO BEACH CA
90278
Install - Billing Option: SCE INSTALL - REFUNDABLE
415 DIAMOND ST
REDONDO BEACH CA 90277
Telephone: (310)-783-9303
REDONDO BEACH, CITY OF
SCE Contact: Amanda Gayle McEvoy
Invoice Date: 06/21/2024
505 MAPLE AVENUE
TORRANCE CA 90503
Southern California Edison Company
Document # 7590561739
Invoice # 549226
Item # 580879
Design #: 1737268
2271151 - LINE EXTENSION
Product: $1,241.86
Previous Payment $0.00
* For Mixed-Fuel projects, payment and signed contracts MUST be received before July 1, 2024, to keep subsidies (allowances, discount/refund options) and estimated cost pricing, otherwise SCE will reprice the project WITHOUT subsidies.
* Effective July 1, 2024, through December 31, 2024, Mixed-Fuel new construction projects (gas or propane in addition to electricity) will not receive subsidies and will be priced as estimated cost. * Effective January 1, 2025, Mixed-Fuel new construction projects will not receive subsidies and will be priced as actual cost billing.
* Enclosed are two copies of your invoice. Please return one copy of the invoice with your payment to Accounts Receivable in the enclosed return-addressed envelope. The other copy of the invoice is for your records. * All payments must be delivered by mail, an alternate postal method, or one of our electronic payment options.
Walk-in payments are no longer accepted at any SCE location, including Accounts Receivable. * Please complete all applications and/or contracts and return to your planning office, using the enclosed return-addressed envelope.
* For the Refundable and Discount Option appendices, choose only one option. Sign "Has Chosen" on the appropriate option and sign "Has Not Chosen" on the other option. Only sign each form once. Return both forms in the enclosed self-addressed envelope.
* If a street light work order is associated with this project, contracts for that project will be enclosed. * Easement documents will be mailed directly to you from our Right of Way department. Please complete and return them as soon as possible, as we will not be able to proceed with the project without clearance * Call the Edison company at 1-800-655-4555 to make application for electrical service. * An Edison Inspector must approve all underground systems. Please call your designated inspector 48 hours prior to construction to schedule an inspection.
* Final electrical inspection from the local governmental building and safety department must be received before we can energize your service.
* By paying this invoice, customer acknowledges and agrees that if this project is canceled by customer for any reason or customer does not proceed with the project completion. * Any expense incurred by SCE, including, but not limited to, expenses related to engineering, inspection and construction, prior to the project cancellation or completion will be deducted from any applicable refund due to the customer.
* To ensure worker and public safety, please maintain the appropriate clearance distance from utility infrastructure during your construction project to avoid encroachments that may result in serious injury or damage. * If relocation of existing utility infrastructure is pending, please adjust your work around the proposed relocation schedule as appropriate. If you have any questions, please contact the designated SCE representative assigned to your project.
$ 1,241.86
COMMENTS:
TOTAL PROJECT INVOICE AMOUNT:
Description Amount
Service Request Number: 3742236 Project:
2430 MANHATTAN BEACH BLVD U PED REDONDO BEACH CA
90278
Install - Billing Option: SCE INSTALL - REFUNDABLE
415 DIAMOND ST
REDONDO BEACH CA 90277
Telephone: (310)-783-9303
REDONDO BEACH, CITY OF
SCE Contact: Amanda Gayle McEvoy
Invoice Date: 06/21/2024
505 MAPLE AVENUE
TORRANCE CA 90503
Southern California Edison Company
Document # 7590561739
Invoice # 549226
Please detach and return payment stub with payment
Payment
Stub
REDONDO BEACH, CITY OF
415 DIAMOND ST
REDONDO BEACH CA 90277
Please pay total amount now due:
$ 1,241.86
Thank you for paying promptly
Make check payable to Southern California Edison
Document # 7590561739
ATTN: Remittance Processing
PO Box 800
Rosemead, CA 91771-001
ADDITIONAL PAYMENT INSTRUCTIONS:
If paying by check, please follow instructions on payment stub JP Morgan Chase Bank
New York, NY
ABA#: 021000021 - Acct#: 323-394434
SCE Taxpayer ID No. 95-1240335
Document #: 7590561739
SCE Contact:
Southern California Edison
Attn: Remittance Processing
G.O. 1 Ground Floor, Room G53
2244 Walnut Grove Ave.
Rosemead, CA 91770
Amanda Gayle McEvoy
Instructions for wire or ACH payments:
*** Failure to properly identify your document number and SCE contact may delay the application of funds and initiation of your project
Special Instructions for overnight delivery methods:
LOC. W.O. A.I.
APPENDIX A - REFUNDABLE OPTION
ELECTRIC LINE EXTENSION AGREEMENT
JOB #
07/06/2024
LINE EXTENSION 2271151
1. SCE RULE 16 COST TO SERVE
(A) SCE RULE 16 COST TO SERVE
(B) LESS APPLICANT ALLOWANCES
(C) EXCESS RULE 16 COST TO (LINE 5. (A))
(D) EXCESS ALLOWANCES TO (LINE 2.)
SCE COST TO SERVE RULE 15
(E) OVERHEAD 0 FEET X $.00 UNIT COST $.00
(F) UNDERGROUND
(G) PROJECT SPECIFIC ( IF 2X UNIT COST OR COMPETITIVE BID ) (H) TOTAL SCE RULE 15 COST TO SERVE
0 FEET X $.00 UNIT COST $.00
2 . APPLICANT ALLOWANCES (FROM LINE 1. (D) )
3 . REFUNDABLE :
(A) SCE RULE 15 COST TO SERVE (LINE 1 . (H) )
(B) PLUS ESTIMATED VALUE OF STRUCTURES
(C) SUBTOTAL ( LINE 3 . (A) + 3 . (B) )
(D) LESS ALLOWANCE ( LINE 2 )
(E) REFUNDABLE AMOUNT ( LINE 3 . (C) - 3 . (D) )
(F) PLUS REFUNDABLE ITCC* ON LINE 3. (E)
(G) TOTAL AMOUNT ( LINE 3 . (E) + 3 . (F) )
4 . PAYMENT OPTION SELECTED : REFUNDABLE HAS CHOSEN : SIGN (A) REFUNDABLE OPTION : LINE 3 . (G)
1 )
2 )
3 )
VALUE OF STRUCTURES :
REFUNDABLE PAYMENT :
AMOUNT SUBJECT TO REFUND/CREDIT
5 . OTHER NON-REFUNDABLE ADVANCES & CREDITS
(A) OTHER NON-REFUNDABLE CHARGES
( RULE 16 , FLAT RATE , INSPECTION , R/W , ETC . )
(B) ITCC* ON OTHER NON-REFUNDABLE
(C) ITCC* ON APPLICANT FURNISHED FACILITIES
(D) INSTALLED COST OF SUBSTRUCTURE BY SCE
(E) LESS APPLICANT DESIGN OR REIMBURSABLE CREDITS
(F) TOTAL NON-REFUNDABLE ( LINE 5 . (A) THRU 5 . (D) - 5 . (E) ) (G) TOTAL CREDITS ( LINE 5 . (E) - 5 . (A) THRU 5 . (D) ) 6 . AMOUNT TO BE PAID BY APPLICANT TO SCE
7 . AMOUNT TO BE REFUNDED TO APPLICANT UPON FULFILLMENT OF ALL
CONTRACTUAL OBLIGATIONS
HAS NOT CHOSEN : SIGN
* INCOME TAX COMPONENT OF CONTRIBUTION
$657.37
$12,327.68
$0.00
$11,670.31
$2,467.48
$2,467.48
$11,670.31
$2,467.48
$275.18
$2,742.66
$11,670.31
$0.00
$0.00
$0.00
$0.00
$275.18
$0.00
$275.18
$906.00
$217.44
$393.60
$0.00
$0.00
$1,517.04
$0.00
$1,241.86
$0.00
Applicant :
Product Number :
Project Specific Location :
SCE’s estimated refundable costs:*
SCE Rule 16 credit amount :*
SCE street light credit amount :*
SCE associated work credit amount :*
SOUTHERN CALIFORNIA EDISON ( "SCE " )
DISTRIBUTION LINE AND/OR SERVICE EXTENSION
APPLICANT'S INSTALLATION OPTION AND
STATEMENT OF APPLICANT'S CONTRACT ANTICIPATED COSTS
REDONDO BEACH, CITY OF
2430 MANHATTAN BEACH BLVD CA 90278
$2,467.48
$657.37
$0.00
$0.00
2271151
1. INSTALLATION OPTIONS
Applicant understands that in accordance with SCE’s Rule 15 and/or Rule 16, Applicant can elect to have either SCE install the Distribution Line and/or Service Extension or a Qualified Contractor/Subcontractor install the Distribution Line and/or Service Extension.
2. SCE’S ESTIMATED REFUNDABLE COST INFORMATION
SCE’s estimated refundable costs are based on the work that SCE would normally perform that can be performed by a Qualified Contractor/Subcontractor under the provisions of the Applicant Installation Option, Rule 15, Section G, and in accordance with SCE’s Terms and Conditions Agreement for Installation of Distribution Line Extension by Applicant (Form 14-188).
If applicable, other estimated cost information may be provided below. This could include the credit amount for Rule 16, street light, or other associated installation work.
3. APPLICANT SELECTION
Applicant understands the installation options under Section 1 above, and hereby elects the following installation option by initialing the appropriate selection below:
_________ Installation by SCE
_________ Installation by Qualified Contractor/Subcontractor Under installation by Qualified Contractor/Subcontractor, Applicant shall secure project specific bid information from Qualified Contractors/Subcontractors for the installation of the Distribution Line and/or Service extension.
Applicant shall contribute or advance before the start of construction any refundable or non-refundable amounts as specified in Rules 15 and 16.
*Please refer to the specific contract, Appendix A, for detailed financial information.
Form 14-754, Rev. 1/2024
4. APPLICANT'S CONTRACT ANTICIPATED COST INFORMATION (to be completed only if installation is performed by a Qualified Contractor/Subcontractor as selected in Section 3 above) Option 1 Applicant elects to provide SCE with the Applicants Contract Anticipated Costs, which are subject to refund, that are associated with that portion of the new Distribution Line and/or Service Extension normally installed by SCE, and understands that the lower of SCE's estimated refundable cost or the Applicant's Contract Anticipated Costs, which are subject to refund, as submitted below, shall apply to any applicable SCE refunds and allowances provided in accordance with Rule 15 and 16, 1
or
Option 2 Applicant elects not to provide SCE with the Applicants Contract Anticipated Costs, which are subject to refund. The Applicant understands that by selecting this option, the Applicant is directing SCE to use SCE's estimated refundable cost for all billing and accounting.
Applicant understands the Applicants Cost Information, as described above, and hereby elects the following by initialing the appropriate selection below :
________Option 1 - Applicants Contract Anticipated Costs $ _________________ ________Option 2 - SCE's Estimated Refundable Costs $ _________________
5. ITCC
SCE shall value all trenching, conduit, backfill, street repair, substructures, and encasement, based on SCE's estimate of such items, for the purpose of collecting the applicable governmental taxes (ITCC) on contributions to SCE.
7. UTILITY RESPONSIBILITIES
Upon receipt of this completed and signed form, SCE shall begin the process of producing the applicable contracts and forms based on the selection made by the Applicant.
Applicant and/or Applicant’s Qualified Contractor/Subcontractor understands that for the portion of the Electrical Distribution and/or Service Extension that SCE would normally install, in accordance with SCE’s Rule’s 15 and/or 16 and the Terms and Conditions Agreement for Installation of Distribution Line Extension by Applicant, the Applicant, prior to performing any work associated with the installation of these electrical facilities, and for the purpose of utility billing and accounting, shall elect one of the following options, and return this form to SCE prior to SCE proceeding with any further work on the Applicant’s project.
6. MIXED FUEL NEW CONSTRUCTION PROJECTS
Effective July 1, 2024, Allowances will not apply to Mixed-Fuel New Construction unless otherwise approved by the Commission in accordance with Decision 22-09-026. Effective January 1, 2025, any work performed associated with a Mixed-Fuel New Construction Distribution Line Extension2 project will be based on actual installed cost. Estimated costs will initially apply with final actual costs due after project completion. When an Applicant selects the Applicant Installation Option within Rule 15, reimbursable credits for the value of the substructures installed by the Applicant and deeded to SCE will not apply.
Form 14-754, Rev. 1/2024
8. SIGNATURE CLAUSE
The signatory hereto represents that they have been appropriately authorized into this contract on behalf of the party for whom they sign.
I declare under penalty of perjury that the foregoing is true and correct Applicant : ______________________________________________
Corporation, Partnership, or DBA: ____________________________ Name of Authorized Individual: ______________________________ Applicant’s signature: ______________________________________ Title: ___________________________________
Date: _________________________
1 Excludes the estimated costs of work the Applicant cannot perform, such as, work on or in proximity to, energized equipment.
2 As defined in Rule 15, a Mixed-Fuel New Construction is a building that uses gas and/or propane in addition to electricity, and has never been used or occupied for any purpose Form 14-754, Rev. 1/2024
ATTEST:
______________________________
Eleanor Manzano, City Clerk
APPROVED AS TO FORM:
______________________________
Michael W. Webb, City Attorney
Mayor
James A. Light
Form No. 16
-330 1
Rev. 01/2024
CONTRACT FOR EXTENSION OF ELECTRIC DISTRIBUTION LINE
RULE 15
1. PARTIES
This Contract for Extension of Electric Distribution Line ("Contract") is issued this day of , . The Parties to this Contract are:
REDONDO BEACH, CITY OF
("Applicant")
and Southern California Edison Company ("SCE"). Applicant and SCE are referred to individually as "Party" and collectively as "Parties".
2. RECITALS
Applicant has requested SCE, pursuant to SCE's Rule 15, Distribution Line Extensions, to install an electric Distribution Line Extension to the location or locations described as follows:
2430 MANHATTAN BEACH BLVD U PED REDONDO BEACH CA 90278
(Hereinafter referred to as "Project")
3. AGREEMENT
3.1 Responsibilities of Applicant
Construction
Applicant shall, in accordance with SCE's specifications and timing requirements for the Project: o Perform route clearing, tree trimming, trenching, excavating, and backfilling and compacting;
o Furnish imported backfill material and dispose of trench spoil as required; o Furnish, install and transfer ownership to SCE any substructures, conduit, and protective structures required;
o Obtain any necessary construction permits for all work performed by Applicant under this Contract.
If Applicant elects to have SCE perform any part of this work, Applicant shall pay to SCE, as specified herein and before the start of construction, SCE's estimated-installed costs thereof.
Beginning January 1, 2025, any work performed by SCE associated with a Mixed Fuel New Construction Distribution Line Extension
1 will be based on actual installed cost. Estimated
costs will initially apply with final actual costs due after project completion. 1 Defined in Rule 15 as, “A building that uses gas and/or propane in addition to electricity, and has never been used or occupied for any purpose.”
6TH
AUGUST 2024
Form No. 16-330 2
Rev. 01/2024
Rights of Way
Applicant hereby grants to SCE the rights of way and easements for the Distribution Line Extension over the shortest, most practical, available, and acceptable route within Applicant's property for the purpose of making delivery of electric service hereunder. Such easement shall include the right of access and right to trim trees as necessary. Where formal rights of way, easements, land leases, or permits are required by SCE for installation of facilities on or over Applicant's property, or the property of others, Applicant understands and agrees that SCE shall not be obligated to install the Distribution Line Extension for the Project unless and until any necessary permanent rights of way, easements, land leases, and permits, satisfactory to SCE, are granted to or obtained for SCE without cost to or condemnation by SCE.
Advances
Applicant shall contribute or advance, before the start of construction, the refundable and non-refundable amounts as set forth in Appendix A to this Contract. This includes the costs for substructures and conduits which SCE had previously installed at its expense in anticipation of the current Distribution Line Extension. Any necessary riser conduit, conduit covering, and miscellaneous riser material required for the Distribution Line Extension shall be furnished or paid for by Applicant and shall be installed by SCE.
All contributions and advances by Applicant are taxable and shall include an Income Tax Component of Contribution (ITCC) at the rate provided in SCE's Preliminary Statement.
ITCC will be either refundable or non-refundable depending on whether the corresponding contribution or advance is refundable or non-refundable.
Joint Applicants. The total contribution or advance from joint Applicants will be apportioned by SCE among the members of the group in such manner as Applicants mutually agree.
Effective January 1, 2025, any work performed associated with a Mixed-Fuel New Construction Distribution Line Extension project will be based on actual installed cost.
Estimated costs will initially apply with final actual costs due after project completion.
3.2 Responsibilities of SCE
Construction
SCE shall install, own, operate, and maintain the Distribution Line Extension to serve the Project. SCE will install only those facilities that, in SCE's judgment, will be used within a reasonable time to serve permanent loads.
Refunds
SCE shall make refunds to Applicant in accordance with the provisions of Rule 15.
Effective July 1, 2024, Applicants with Mixed-Fuel New Construction projects are not subject to refunds. Exceptions may apply to non-residential Mixed-Fuel New Construction projects if approved by the CPUC.
Form No. 16-330 3
Rev. 01/2024
3.3 Ownership of Facilities
Title to and ownership of the Distribution Line Extension shall vest in SCE. Applicant does hereby agree that upon completion and acceptance by SCE of any Applicant-installed facilities, title to each and every component part thereof shall immediately pass to SCE free and clear of all liens and encumbrances.
3.4 Service Facilities
Service extensions shall be installed pursuant to SCE's Rule 16, Service Extensions.
3.5 Street Lighting Facilities
Street lighting and Distribution Line Extensions within the Project solely for service to street lighting equipment shall be installed in accordance with the appropriate street light tariff schedule. Street light revenues are not applicable toward allowances or refunds for Distribution Line Extensions. Electroliers shall be located at points determined by the governmental agency having jurisdiction over streets to be dedicated to that agency or by Applicant for privately owned and maintained streets open to and used by the general public.
3.6 Non-Refundable Discount Option
In lieu of contributing the total refundable amount, Applicant has the option of contributing, on a non-refundable basis, a percentage of such refundable amount as set forth in Appendix A to this Contract. Applicant has or has not chosen this option as indicated by signature on Appendix A.
Effective July 1, 2024, Applicants with Mixed-Fuel New Construction projects are not eligible for the Non-Refundable Discount Option. Exceptions may apply to non-residential Mixed-Fuel New Construction projects if approved by the CPUC.
3.7 Refunds
The total refundable amount shall be subject to refund, without interest, in accordance with the provisions of Rule 15, which include the following:
Residential. Refunds will be made on the basis of any new customer permanent load connected to the Distribution Line Extension which produces additional revenues to SCE.
The refund will be deducted from the total refundable amount, and the remaining amount subject to refund will represent that portion of the Distribution Line Extension cost not supported by revenues.
Non-Residential. Refunds will be made on the basis of Applicant or any new customer permanent load connected to the Distribution Line Extension which produces additional revenues to SCE. SCE shall be responsible to review Applicant's actual net revenue for the first three years from the date SCE is first ready to serve. Applicant shall be responsible for notifying SCE if new, permanent load is added the fourth through tenth year from the date SCE is first ready to serve. Such review shall determine if additional net revenue justifies refunds to Applicant.
Unsupported Distribution Line Extension Cost. When any portion of a refundable amount has not qualified for a refund at the end of twelve (12) months from the date SCE is first ready to serve, Applicant will pay to SCE a Monthly Ownership Charge on the remaining refundable balance. The difference between the total refundable advance and any refunds made or Form No. 16-330 4
Rev. 01/2024
eligible to be made to Applicant shall serve as the basis of a monthly ownership charge ("base"). The Monthly Ownership Charge includes replacement for 60 years at no additional cost and is derived from the Customer-Financed With Replacement at Additional Cost Added Facilities rates determined in SCE’s general rate case proceeding and/or periodic annual review. Monthly ownership charges are distinct from the refundable amount and will normally be accumulated and deducted from refunds due to Applicant. This provision does not apply to individual residential Applicants.
The Monthly Ownership Charge herein shall automatically increase or decrease if the California Public Utilities Commission should subsequently authorize a higher or lower percentage rate for the Monthly Ownership Charge, effective on the date of such authorization.
Refund Period. The total refundable amount is subject to refund for a period of ten (10) years after the Distribution Line Extension is first ready to serve. Any unrefunded amount remaining at the end of the ten-year period shall become property of SCE.
3.8 Payment Adjustments
Contract Compliance. If, after six (6) months following the date SCE is first ready to serve residential loads for which allowances were granted, one (1) year for non-residential loads, Applicant fails to take service, or fails to use the service contracted for, Applicant shall pay to SCE an additional contribution, based on the allowances for the revenue actually generated.
Excess Facilities. If the load information provided by Applicant results in SCE having installed facilities which are in excess of those needed to serve the actual loads, and SCE elects to reduce such excess facilities, Applicant shall pay to SCE its estimated total costs to remove, abandon, or replace the excess facilities, less the estimated salvage of any removed facilities.
Mixed-Fuel New Construction. Effective July 1, 2024, allowances will not be provided to Mixed-Fuel New Construction projects. Additionally, Effective January 1, 2025, any work performed associated with a Mixed-Fuel New Construction Distribution Line Extension project will be based on actual installed cost. Estimated costs will initially apply with final actual costs due after project completion.
Mixed-Fuel New Construction projects currently in the development process will receive applicable subsidies (e.g., Allowances, Refunds, Non-Refundable Discount Option) if said project meets all the criteria below. If the criteria below are not met, estimated costs will initially apply with final actual costs due after project completion:
(1) The invoice has been paid to SCE as of July 1, 2024; (2) The applicable SCE contract(s) was signed and received by SCE as of July 1, 2024; and
(3) The project(s) is field complete/energized no later than 12 months after July 1, 2024.
3.9 Reimbursement to Applicant
Where mutually agreed upon by SCE and Applicant, Applicant may perform SCE's work or install facilities normally installed by SCE. Such work shall be in accordance with SCE's specifications and timing requirements. SCE shall reimburse Applicant SCE's estimated installed cost of such facilities and work by applying a credit toward Applicant's advance. Any amount not so credited shall be reimbursed to Applicant upon acceptance of the work and Form No. 16-330 5
Rev. 01/2024
facilities by SCE.
3.10 Delays in Construction
Force Majeure. SCE shall not be responsible for any delay in the installation or completion of the facilities by SCE resulting from the late performance of Applicant's responsibilities under this Contract, shortage of labor or material, strike, labor disturbance, war, riot, weather conditions, governmental rule, regulation or order, including orders or judgements of any court or commission, delay in obtaining necessary land rights, act of God, or any other cause or condition beyond the control of SCE.
Resources. SCE shall have the right, in the event it is unable to obtain sufficient supplies, materials, or labor for all of its construction requirements, to allocate materials and labor to construction projects which it deems, in its sole discretion, most important to serve the needs of its customers. Any delay in construction hereunder resulting from such allocation shall be deemed to be cause beyond SCE's control.
Contract Revision. If Applicant does not commence installation of any facilities which are Applicant's responsibility or SCE is prevented from commencing the installation of the facilities for causes beyond its reasonable control within one year from the effective date of this Contract, SCE may, in its discretion, revise its cost estimate and recalculate the refundable and/or non-refundable amounts set forth herein. SCE will notify Applicant of such increased costs and give the option to either terminate this Contract or pay SCE the additional charges.
See Section 3.8 above for criteria and associated dates regarding Mixed-Fuel New Construction currently in the development process.
3.11 Contract Termination
If at any time during the term of this Contract, SCE is not the sole deliverer of electrical requirements for the Project, this Contract may be terminated. Upon termination of the Contract, Applicant agrees to forfeit that portion of the advance paid to SCE for its expenses covering any engineering, surveying, right of way acquisition and other associated work incurred by SCE. If such expenses are greater or less than the refundable and/or nonrefundable advance, Applicant shall pay to SCE, or SCE shall refund the balance to Applicant, without interest, as the case may be.
3.12 Indemnification
Applicant shall, at its own cost, defend, indemnify, and hold harmless SCE, its officers, agents, employees, assigns, and successors in interest from and against any and all liability, damages, losses, claims, demands, actions, causes of action, costs including attorney's fees and expenses, or any of them, resulting from the death or injury to any person or damages to any property caused by Applicant or its contractor and employees, officers or agents of either Applicant or its contractor, or any of them, and arising out of the performance or nonperformance of their obligations under this Contract.
3.13 Assignment of Contract
Applicant may assign this Contract, in whole or in part, only if SCE consents in writing and the party to whom the Contract is assigned agrees in writing, to perform the obligations of Applicant hereunder. Assignment of the Contract shall not release Applicant from any of the obligations under this Contract unless otherwise provided therein.
Form No. 16-330 6
Rev. 01/2024
3.14 Joint and Several Liability
Where two or more individuals or entities are joint Applicants under this Contract, all Applicants shall be jointly and severally liable to comply with all terms and conditions herein.
3.15 Warranty
Applicant warrants that all work and/or equipment furnished or installed by Applicant or its contractor shall be free of defects in workmanship and material. The warranty period shall begin from the date of final acceptance by SCE and extend for one (1) year. Should the work develop defects during that period, SCE, at its election, shall either (a) repair or replace the defective work and/or equipment, or (b) demand that Applicant repair or replace the defective work and/or equipment and, in either event, Applicant shall be liable for all costs associated with such repair and/or replacement. Applicant upon demand by SCE, shall promptly correct, to SCE's satisfaction and that of any governmental agency having jurisdiction, any breach of any warranty.
3.16 Contract Effective Date
This Contract shall not be effective unless it is (1) signed by SCE’s authorized individual, (2) executed and delivered by Applicant to SCE together with payment required hereunder within ninety (90) days of the date in Paragraph 1 of this Contract and (3) accepted by SCE. This Contract shall then be effective on the date executed by SCE and shall take effect without further notice to Applicant.
3.17 Commission Jurisdiction
This Contract is subject to the applicable provisions of SCE's tariffs, including Rule 15, filed and authorized by the California Public Utilities Commission.
This Contract shall, at all times, be subject to such changes or modifications by the Public Utilities Commission of the State of California, as said Commission may, from time to time, direct in the exercise of its jurisdiction.
3.18 Completion Date
The completion date requested by Applicant is .
4. SIGNATURE CLAUSE
The signatories hereto represent that they have been appropriately authorized to enter into this Contract on behalf of the party for whom they sign.
APPLICANT(S)
CORPORATION, PARTNERSHIP, OR DBA:
NAME OF AUTHORIZED INDIVIDUAL:
SIGNATURE:
James A. Light
ATTEST:
______________________________
Eleanor Manzano, City Clerk
APPROVED AS TO FORM:
______________________________
Michael W. Webb, City Attorney
Form No. 16-330 7
Rev. 01/2024
TITLE:
MAILING ADDRESS:
TELEPHONE:
ADDITIONAL SIGNATURES FOR JOINT APPLICANTS
NAME OF AUTHORIZED INDIVIDUAL:
SIGNATURE:
TITLE:
MAILING ADDRESS:
TELEPHONE:
NAME OF AUTHORIZED INDIVIDUAL:
SIGNATURE:
TITLE:
MAILING ADDRESS:
TELEPHONE:
APPORTIONMENT OF ADVANCE AMONG JOINT APPLICANTS:
SOUTHERN CALIFORNIA EDISON COMPANY
NAME OF AUTHORIZED INDIVIDUAL:
SIGNATURE:
TITLE:
DATE EXECUTED:
PRODUCT NO. 2271151
Mayor
415 Diamond Street, Redondo Beach, CA 90277