Item 13 2024-01522 Contract - Old Sacramento Parking Garage Painting V15510000 — Sacramento City Council, September 10, 2024

City of Sacramento
City Council - 5PM Report
915 I Street Sacramento, CA 95814
www.cityofsacramento.org
File ID: 2024-01522 9/10/2024 Consent Item 13.

Contract: Old Sacramento Parking Garage Painting V15510000 File ID: 2024-01522
Location: 125 I Street, District 4, Represented by Councilmember Valenzuela Recommendation: Pass a Motion: 1) authorizing the use of the Request for Qualification Q23014541001 for On-Call (Various) Trade Opportunities to satisfy the competitive selection requirements for this contract; 2) awarding a construction contract to Blackhawk Painting, Inc. in an amount not to exceed $542,500 for the Old Sacramento Parking Garage Painting Project; and 3) authorizing the City Manager or the City Manager’s designee to execute the contract specified above.

Contact: Norm Colby, Facilities & Real Property Superintendent, (916) 808-8335, [email protected]; James Christensen, Facilities Manager, (916) 808-5863, [email protected]; Department of Public Works Presenter: None
Attachments:
1-Description/Analysis
2-Contract- Blackhawk Painting, Inc.

Description/Analysis
Issue Detail: The Old Sacramento Historic District is a historic area located in downtown Sacramento, covering approximately 28 acres. This district is a beloved destination for both locals and tourists, celebrated for its meticulously preserved Gold Rush-era architecture, charming cobblestone streets, and rich historical significance.

With the paint on the old Sacramento Parking Garage having outlasted its useful life, maintenance is now required. It is essential to maintain the aesthetics and functionality of public parking garages within this historic district. Powerwashing, repainting these structures, and repairing the railings are crucial steps in ensuring they remain safe, operational, and visually appealing. These actions enhance the overall user experience and allow the garages to seamlessly integrate into the historic ambiance of Old Sacramento, contributing to the district's charm and preserving its unique character for future generations.

Page 1 of 3 ends

File ID: 2024-01522 9/10/2024 Consent Item 13.

Policy Considerations: The recommendations in this report are in accordance with the provisions of City Code Chapter 3.56, which requires City Council approval for contracts over $250,000 or more.

On May 30,2023, the City Council passed Motion No. 2023-0131 suspending competitive bidding in the best interest of the City and authorizing the establishment of a qualified On-Call Services list for Public Facilities improvements.

Economic Impacts: The recommended contract is expected to create 4.01 jobs (2.55 direct jobs and 1.46 job through indirect and induced activities) and create $529,763 in total economic output ($339,592 of direct output and another $190,171 of output in indirect and induced activities).

The indicated economic impacts are estimates calculated using a calculation tool developed by the Center for Strategic Economic Research (CSER). CSER utilized the IMPLAN input-output model (2009 coefficients) to quantify the economic impacts of a hypothetical $1 million of spending in various construction categories within the City of Sacramento in an average one-year period. Actual impacts could differ significantly from the estimates and neither the City of Sacramento nor CSER shall be held responsible for consequences resulting from such differences.

Environmental Considerations:

California Environmental Quality Act: No environmental review is necessary because the recommendations in this report involve the repair of an existing structure with no expansion beyond the previously existing level of use and are therefore considered to be an exempt project or activity in accordance with Section 15301 of the CEQA Guidelines.

Sustainability: None.

Commission/Committee Action: Not applicable.

Rationale for Recommendation: On January 11, 2023, the Department of Public Works issued Request for Qualification (RFQ) No. Q23014541001 for On Call (Various) Trade Opportunity. One of the categories that was requested as part of this process was Painting services. On May 30, 2023, City Council passed Motion No. 2023-0131 suspending competitive bidding in the best interest of the City to establish a qualified On- Call Contactor Services List for Public Facilities. Blackhawk Painting, Inc. was included in the list of qualified On-Call Contractors for the Painting services. The establishment of the list of qualified On Call Contractors was created to provide timely services, when specialized work is required, or when operations of essential facilities are being interrupted. The City does not have staff that can perform painting on such a large scale as the parking garage. Timely repainting will prevent further deterioration of the garage surfaces.

Work is anticipated to begin in October of 2024 with completion by December of 2024.

Page 2 of 3 ends

File ID: 2024-01522 9/10/2024 Consent Item 13.

Financial Considerations: There is sufficient Parking Fund (Fund 6004) in the City Parking Project (V15510000) to award the contract to Blackhawk Painting, Inc, in the amount of $542,500 and to cover the remaining project costs.

Local Business Enterprise (LBE): Blackhawk Painting, Inc. is not an LBE but has partnered with LBE, Dunn Edwards Paint for this project to exceed minimum LBE participation requirement. Dunn Edwards Paint will provide the paint that will be used on this project

Page 3 of 3 ends

Form approved by City Attorney 6-23-23 1

AGREEMENT
(Construction Contract Over $25,000)

THIS AGREEMENT, dated for identification , 2024, is made and entered into between the CITY OF SACRAMENTO, a municipal corporation (“City”), and BLACKHAWK PAINTING, INC., 821 Eubanks Dr. Suite A, Vacaville, CA 95688, (“Contractor”) in the amount of FIVE HUNDRED FORTY-TWO THOUSAND FIVE HUNDRED DOLLARS AND ZERO CENTS ($542,500.00).

The City and Contractor hereby mutually agree as follows:

1. CONTRACT DOCUMENTS

The Contract Documents, sometimes also referred to as the “Contract,” consist of the following items, which are hereby incorporated by reference as if set forth in full in this Agreement:

Notice to Contractors
Proposal Form submitted by the Contractor
Instructions to Bidders
Subcontractor and Local Business Enterprise Participation Form Drug-Free Workplace Policy and Affidavit
Construction and Demolition (C&D) Debris Recycling Requirements Workers’ Compensation Insurance Certification
Federal or State funding requirements (if applicable)
Local Business Enterprise (LBE) Requirements
Requirements of the Non-Discrimination in Employee Benefits Code Ban-The-Box Requirements
Addenda, if any
This Agreement
Standard Specifications
Special Provisions
Plans and Technical Specifications
The drawings and other data and all developments thereof prepared by City pursuant to the Contract
Any modifications of any of the foregoing made or approved by City, including but not limited to duly authorized change orders

Unless specifically noted otherwise, references to the “Standard Specifications ” shall mean and refer to the Standard Specifications for Public Construction of the City of Sacramento approved by the Sacramento City Council on November 10, 2020 (Resolution No. 2020-0354), and any subsequent amendments thereto approved by the Sacramento City Council or the Sacramento City Manager . Work called for in any one Contract Document and not mentioned in another is to be performed and executed as if mentioned in all Contract Documents. The table of contents, titles and headings contained in the Contract Documents are provided solely to facilitate reference to various provisions of the Contract Documents and in no way affect or limit the interpretation of the provisions to which they refer.

Form approved by City Attorney 6-23-23 2

2. DEFINITIONS

Unless otherwise specifically provided herein, all words and phrases defined in the Standard Specifications shall have the same meaning and intent in this Agreement.

3. AGREEMENT CONTROLS

In the event of a conflict between any of the terms and conditions set forth in this Agreement and the terms and conditions set forth in other Contract Documents, the terms and conditions set forth in this Agreement shall prevail, except that the provisions of any duly authorized change order shall prevail over any conflicting provisions of this Agreement.

4. SCOPE OF CONTRACT

Contractor agrees to furnish all tools, equipment, apparatus, facilities, labor , material, and transportation necessary to perform and complete in a good and workmanlike manner to the satisfaction of City, all the Work called for in the Contract Documents entitled:

OLD SACRAMENTO GARAGE PAINTING
PN: (V15510001)

Including the Work called for in the following alternative bid items described in the Proposal Form:

Contractor agrees to perform such Work in the manner designated in and in strict conformity with the Contract Documents.

5. CONTRACT AMOUNT AND PAYMENTS

City agrees to pay, and Contractor agrees to accept, as complete payment for the above Work, in accordance with the schedule and procedures set forth in the Contract Documents and subject to deductions, withholdings and additions as specified in the Contract Documents, a total sum that shall not exceed the total bid amount set forth in Contractor’s Proposal Form . In addition, subject to deductions, withholdings, and additions as specified in the Contract Documents , payment for individual items of the Work shall be computed as follows:

A. For items of the Work for which a lump sum price is specified in Contractor’s Proposal Form , Contractor shall be paid the lump sum price(s) specified in Contractor’s Proposal Form; and

B. For items of the Work for which a unit price is specified in Contractor’s Proposal Form, Contractor shall be paid the sum computed at such unit price, or computed at a different price if such different price is determined by City in accordance with the Standard Specifications, based on the actual amount of each such item Form approved by City Attorney 6-23-23 3
performed and/or furnished and incorporated in the Work ; provided that in no event shall the total sum for a unit price item exceed the total bid amount set forth for such item in the Contractor’s Proposal Form, unless authorized by Change Order.

6. PROGRESS PAYMENTS

Subject to the terms and conditions of the Contract, City shall cause payments to be made upon demand of Contractor as follows:

A. On or about the first of the month, the Engineer shall present to the Contractor a statement showing the amount of labor and materials incorporated in the Work through the twentieth (20) calendar day of the preceding month . After both Contractor and Engineer approve the statement in writing, and the City’s labor compliance officer provides written approval, the City shall issue a certificate for ninety-five (95) percent of the amount it shall find to be due, subject to any deductions or withholdings authorized or required under the Contract or any applicable Laws or Regulations.

B. No inaccuracy or error in said monthly estimates shall operate to release Contractor from damages arising from such Work or from enforcement of each and every provision of the Contract Documents, and City shall have the right subsequently to correct any error made in any estimate for payment.

C. Contractor shall not be paid for any defective or improper Work.

D. The remaining five (5) percent of the value of the Work performed under the Contract, if unencumbered and subject to any deductions or withholdings authorized or required under the Contract or any applicable Laws or Regulations, shall be released not later than sixty (60) days after completion and final acceptance of the Work by City. Acceptance by Contractor of the final payment shall constitute a waiver of all claims against the City arising under the Contract Documents, except for disputed claims in stated amounts that the Contractor specifically reserves in writing , but only to the extent that the Contractor has complied with all procedures and requirements applicable to the presentation and processing of such claim(s) under the Contract Documents. Contractor shall be entitled to substitute securities for retention or to direct that payments of retention be made into escrow, as provided in Public Contract Code Section 22300, upon execution of the City’s Escrow Agreement for Security Deposits in Lieu of Retention.

E. The parties agree that, for purposes of the timely progress payment requirements specified in Public Contract Code Section 20104.50, the date that the City receives a statement jointly approved by the Contractor and the Engineer as provided above shall be deemed to constitute the date that City receives an undisputed and properly submitted payment request from the Contractor. Progress payments not made within 30 days after this date may be subject to payment of interest as provided in Public Contract Code Section 20104.50.

Form approved by City Attorney 6-23-23 4
F. This Contract is subject to compliance monitoring and enforcement by the California Department of Industrial Relations, as specified in California Labor Code section 1771.4.

7. RETENTION OF SUMS CHARGED AGAINST CONTRACTOR

When, under the provisions of this Contract or any applicable Laws or Regulations, City is authorized or required to withhold, deduct, or charge any sum of money against Contractor, City may deduct and retain the amount of such charge from the amount of the next succeeding progress estimate(s), or from any other moneys due or that may become due Contractor from City. If, on completion or termination of the Contract, sums due Contractor are insufficient to pay City's charges, City shall have the right to recover the balance from Contractor or its Sureties.

8. COMMENCEMENT AND PROSECUTION OF WORK

Contractor shall commence the Work not later than fifteen (15) working days after the date of the written Notice to Proceed from City to Contractor and shall diligently prosecute the W ork t o final completion. The phase “ commence the W ork” means to engage in a continuous program on- site including, but not limited to, site clearance, grading, dredging, land filling and the fabrications, erection, or installation of the Work.

The Notice to Proceed shall be issued within fifteen (15) calendar days following execution of the Agreement by the City and the filing by Contractor of the required Bonds and proof of insurance, provided that the Engineer may delay issuance of the Notice to Proceed if the Engineer determines in the Engineer’s sole discretion that conditions on the site of the Work are unsuitable for commencement of the Work . After the Notice to Proceed is issued, the continuous prosecution of Work by Contractor shall be subject only to Excusable Delays as defined in this Agreement.

9. TIME OF COMPLETION

The entire Work shall be brought to completion in the manner provided for in the Contract Documents on or before SIXTY (60) CALENDAR days from the date of the Notice to P roceed (hereinafter called the “ Completion Date”) unless extensions of time are granted in accordance with the Contract Documents.

Failure to complete the entire Work by the Completion Date and in the manner provided for in the Contract Documents shall subject Contractor to liquidated damages as provided in this Agreement. Time is and shall be of the essence in the performance of the Contract and the Work.

10. PAYMENTS DO NOT IMPLY ACCEPTANCE OF WORK

The payment of any progress payment, or the acceptance thereof by Contractor, shall not constitute acceptance of the Work or any portion thereof and shall in no way reduce the liability of Contractor to replace unsatisfactory work or material, whether or not the unsatisfactory character of such work or material was apparent or detected at the time such payment was made.

Form approved by City Attorney 6-23-23 5

11. ACCEPTANCE NOT RELEASE

Contractor shall correct immediately any defective or imperfect work or materials that may be discovered before final acceptance of the entire Work, whether or not such defect or imperfection was previously noticed or identified by the City . The inspection of the Work, or any part thereof, shall not relieve Contractor of any of its obligations to perform satisfactory work as herein specified.

Failure or neglect on the part of City or any of its officers, employees or authorized agents to discover, identify, condemn or reject defective or imperfect work or materials shall not be construed to imply an acceptance of such work or materials , if such defect or imperfection becomes evident at any time prior to final acceptance of the entire Work, nor shall such failure or neglect be construed as barring City from enforcing Contractor’s warranty(ies) or otherwise recovering damages or such a sum of money as may be required to repair or rebuild the defective or imperfect work or materials whenever City may discover the same, subject only to any statu tes of limitation that may apply to any such claim.

12. CITY'S RIGHT TO TAKE POSSESSION OF THE WORK IN WHOLE OR IN PART

The City shall have the right at any time to enter upon the Work and perform work not covered by this Contract, or to occupy and use a portion of the Work, prior to the date of the final acceptance of the Work as a whole, without in any way relieving Contr actor of any obligations under this Contract.

13. NO WAIVER OF REMEDIES

Neither the inspection by City , its officers, employees or agents, nor any certificate or other approval for the payment of money, nor any payment for, nor acceptance of the whole or any part of the Work by City, nor any extensions of time, nor any position taken by City, its officers, employees or its agents shall operate as a waiver of any provision of the Contract Documents nor of any power herein reserved to City or any right to damages herein provided, nor shall any waiver of any breach of this Agreement be held to be a waiver of any other or subsequent breach. All remedies provided in the Contract Documents shall be taken and construed as cumulative; in addition to each and every other remedy herein provided, the City shall have any and all equitable and legal remedies that it would in any case have.

14. WARRANTY

Except as otherwise expressly provided in the Contract Documents, and excepting only items of routine maintenance, ordinary wear and tear and unusual abuse or neglect by City, Contractor warrants and guarantees all Work executed and all supplies, materials and devices of whatsoever nature incorporated in or attached to the Work, or otherwise provided as a part of the Work pursuant to the Contract, to be absolutely free of all defects of workmanship and materials for a period of one year after final acceptance of the entire Work by the City. Contractor shall repair or replace all work or material, together with any other work or material that may be displaced or damaged in so doing, that may prove Form approved by City Attorney 6-23-23 6
defective in workmanship or material within this one-year warranty period without expense or charge of any nature whatsoever to City.

In the event that Contractor shall fail to comply with the conditions of the foregoing warranty within ten (10) days after being notified of the defect in writing, City shall have the right, but shall not be obligated, to repair, or obtain the repair of, the defect and Contractor shall pay to City on demand all costs and expense of such repair.

Notwithstanding anything herein to the contrary, in the event that any defect in workmanship or material covered by the foregoing warranty results in a condition th at constitutes an immediate hazard to public health or safety, or any property interest, or any person, City shall have the right to immediately repair, or cause to be repaired, such defect, and Contractor shall pay to City on demand all costs and expense of such repair.

The foregoing statement relating to hazards to health, safety or property shall be deemed to include both temporary and permanent repairs that may be required as determined in the sole discretion and judgment of City.

In addition to the above, the Contractor shall make a written assignment of all manufacturers and other product warranties to the City, prior to completion and final acceptance of the Work by City.

The Contractor’s Performance Bond shall secure the performance of the Contractor’s obligations under this Section 14 , and the Contractor and its Surety shall be jointly and severally liable for these obligations.

15. LIQUIDATED DAMAGES IF WORK NOT COMPLETED ON TIME

A. The actual fact of the occurrence of damages and the actual amount of the damages that City would suffer if the entire Work, and/or any specified portion thereof, were not completed within the time(s) specified herein are dependent upon many circumstances and conditions that could prevail in various combinations, and for this reason, it is impracticable and extremely difficult to fix the actual damages. Damages that City would suffer in the event of such delay include: loss of the use of the project; expenses of prolonged assignment to the project of an architectural and /or engineering staff; prolonged costs of administration, inspection, and supervision; increased operational expenses and/or impaired operation of other facilities dependent upon completion of the project; and the loss and inconvenience suffered by the public within the City of Sacramento by reason of the delay in the completion of the project or portion thereof. Accordingly, the parties agree, and by execution of this Agreement, Contractor acknowledges that it understands and agrees, that the amount(s) set forth herein as liquidated damages reflect the parties’ best efforts at the time of entering into the Contract to estimate the damages that may be incurred by City and the public due to the Contractor’s delay in completion of the Work and/or any specified portion thereof , and shall be presumed to be the amount of damages sustained by the failure of Contractor to complete the entire Work and/or any specified portion thereof within the time(s) specified herein.

Form approved by City Attorney 6-23-23 7
B. Contractor shall pay liquidated damages to City for failure to complete the entire Work by the Completion Date (as extended in accordance with the Contract Documents, if applicable) in the amount of $ 1000.00 a day for each calendar day after the Completion Date (as extended in accordance with the Contract Documents, if applicable) , continuing to the time at which the entire Work is completed. Such amount is the actual cash value agreed upon by the City and Contractor as the loss to City and the public resulting from Contractor's default.

The parties agree, and by execution of this Agreement, Contractor acknowledges that it understands and agrees, that the foregoing provisions provide for the imposition of liquidated damages from the Completion Date (as extended in accordance with the Contr act Documents, if applicable) until the date of completion of the entire Work as determined by the Engineer in accordance with Section 8-4 of the Standard Specifications, whether or not the Work or any portion thereof is claimed or determined to be substan tially complete prior to such date of completion.

C. In the event Contractor shall become liable for liquidated damages, City, in addition to all other remedies provided by law, shall have the right to withhold any and all payments that otherwise would be or become due Contractor until the liability of Contractor under this section is finally determined. City shall have the right to use and apply such payments, in whole or in part, to reimburse City for all liquidated damages due or to become due to City. Any remaining balance of such payments shall be paid to Contractor only after discharge in full of all liability incurred by Contractor under this section or otherwise under any provision of the Contract Documents or any applicable Law or Regulation. If the sum so retained by City is not sufficient to discharge all such liabilities of Contractor, Contractor shall continue to remain liable to City until all such liabilities are satisfied in full.

No failure by City to withhold any payment as specified above shall in any manner be construed to constitute a release of any such liabilities nor a waiver of the City’s right to withhold payment for such liabilities.

16. INDEMNITY AND HOLD HARMLESS

A. Contractor shall defend, hold harmless and indemnify the City, its officers, employees, and agents, and each and every one of them, from and against any and all actions, damages, costs, liabilities, claims, demands, losses, judgments, penalties, costs and expenses of every type and description, whether arising on or off the site of the Work, including, but not limited to, any fees and/or costs reasonabl y incurred by City’ s staff attorneys or outside attorneys and any fees and expenses incurred in enforcing this provision (hereafter collectively referred to as “Liabilities”), including but not limited to Liabilities arising from personal injury or death, damage to personal, real or intellectual property or the environment, contractual or other economic damages, or regulatory penalties, arising out of or in any way connected with performance of or failure to perform the Work by the Contractor, any subcontractor or agent, anyone directly or indirectly employed by any of them or anyone for whose acts any of th em may be liable, whether or not (i) such Liabilities are Form approved by City Attorney 6-23-23 8
caused in part by a party indemnified hereunder , or (ii) such Liabilities are litigated, settled or reduced to judgment; provided that the foregoing indemnity does not apply to liability for damages for death or bodily injury to persons, injury to property, or other loss, damage or expense to the extent arising from (i) the sole negligence or willful misconduct of, or defects in design furnished by, City, its agents, servants, or independent contractors who are directly responsible to City, or (ii) the active negligence of City.

B. The existence or acceptance by City of any of the insurance policies or coverages described in this Agreement shall not affect or limit any of City’s rights under this Section 16, nor shall the limits of such insurance limit the liability of Contractor hereunder. The provisions of this Section 16 shall survive any expiration or termination of the Contract.

17. CONTRACTOR SHALL ASSUME RISKS

Until the completion and final acceptance by City of all Work under this Contract, the Work shall be under Contractor's responsible care and charge, and Contractor, at no cost to City, shall rebuild, repair, restore and make good all injuries, damages, re- erections, and repairs occasioned or rendered necessary by accidental causes of any nature, to all or any portions of the Work.

18. GENERAL LIABILITY OF CONTRACTOR

Except as otherwise herein expressly stipulated, Contractor shall perform all the Work and furnish all the labor, materials, tools, equipment, apparatus, facilities, transportation, power and light, and appliances, necessary or proper for performing and completing the Work herein required in the manner and within the time herein specified. The mention of any specific duty or liability of Contractor shall not be construed as a limitation or restriction of any general liability or duty of Contractor, and any reference to any specific duty or liability shall be construed to be solely for the purpose of explanation.

19. INSURANCE

During the entire term of the Contract, Contractor shall maintain the insurance coverage described in this Section 19.

Full compensation for all premiums that Contractor is required to pay for the insurance coverage described herein shall be included in the compensation specified for the Work performed by Contractor under this Contract. No additional compensation will be provided for Contractor’s insurance premiums. Any available insurance proceeds in excess of the specified minimum limits and coverages shall be available to the City.

It is understood and agreed by the Contractor that its liability to the City shall not in any way be limited to or affected by the amount of insurance coverage required or carried by the Contractor in connection with this Contract.

Form approved by City Attorney 6-23-23 9
A. Minimum Scope & Limits of Insurance Coverage

(1) Commercial General Liability Insurance providing coverage at least as broad as ISO CGL Form 00 01 on an occurrence basis for bodily injury, including death, of one or more persons, property damage, and personal injury, arising out of activities performed by or on behalf of Contractor and its subcontractors, products and completed operations of Contractor and its subcontractors, and premises owned, leased, or used by Contractor and its subcontractors, with limits of not less than two million dollars ($ 2,000,000) per occurrence. The policy shall provide contractual liability and products and completed operations coverage for the term of the policy.
(2) A
utomobile Liability Insurance providing coverage at least as broad as ISO Form CA 00 01 for bodily injury, including death, of one or more persons, property damage, and personal injury, with limits of not less than one million dollars ($ 1,000,000) per accident. The policy shall provide coverage for owned, non- owned, and/or hired autos as appropriate to the operations of the Contractor.

No automobile liability insurance shall be required if Contractor completes the following certification:

“I certify that a motor vehicle will not be used in the performance of any work or services under this agreement.” ________ (Contractor initials)

(3) Excess Insurance: The minimum limits of insurance required above may be satisfied by a combination of primary and umbrella or excess insurance coverage; provided that any umbrella or excess insurance shall contain, or be endorsed to contain, a provision that it shall appl y on a primary basis for the benefit of the CITY, and any insurance or self- insurance maintained by CITY, its officials, employees, or volunteers shall be in excess of such umbrella or excess coverage and shall not contribute with it.

(4) Workers’ Compensation Insurance with statutory limits, and Employers’ Liability Insurance with limits of not less than one million dollars ($1,000,000). The Workers’ Compensation policy shall include a waiver of subrogation in favor of the City.

No Workers’ Compensation insurance shall be required if Contractor completes the following certification:

Form approved by City Attorney 6-23-23 10
“I certify that my business has no employees, and that I do not employ anyone. I am exempt from the legal requirements to provide Workers' Compensation insurance.” _________
(Contractor initials)

B. Additional Insured Coverage

(1) Commercial General Liability Insurance: The City, its officials, employees, and volunteers shall be covered by policy terms or endorsement as additional insureds as respects general liability arising out of: activities performed by or on behalf of Contractor and its subcontractors; products and completed operations of Contractor and its subcontractors; and premises owned, leased, or used by Contractor and its subcontractors.

(2) Automobile Liability Insurance: The City, its officials, employees, and volunteers shall be covered by policy terms or endorsement as additional insureds as respects auto liability.

C. Other Insurance Provisions

The policies are to contain, or be endorsed to contain, the following provisions:

(1) Contractor’s insurance coverage, including excess insurance, shall be primary insurance as respects City, its officials, employees, and volunteers. Any insurance or self -insurance maintained by City, its officials, employees, or volunteers shall be in excess of Contractor’s insurance and shall not contribute with it.

(2) Any failure to comply with reporting provisions of the policies shall not affect coverage provided to City, its officials, employees, or volunteers.

(3) Coverage shall state that Contractor’s insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer’s liability.

(4) City will be provided with thirty (30) days written notice of cancellation or material change in the policy language or terms.

D. Acceptability of Insurance

Insurance shall be placed with insurers with a Bests’ rating of not less than A:VI. Self -insured retentions, policy terms or other variations that do not comply with the requirements of this Section 3 must be declared to and approved by the City in writing prior to execution of this Contract.

E. Verification of Coverage
Form approved by City Attorney 6-23-23 11

(1) Contractor shall furnish City with certificates and required endorsements evidencing the insurance required. Copies of policies shall be delivered to the City on demand. Certificates of insurance shall be signed by an authorized representative of the insurance carrier.

(2) For all insurance policy renewals during the term of this Contract, Contractor shall send insurance certificates reflecting the policy renewals directly to:

City of Sacramento
c/o EXIGIS LLC
P.O. Box 947
Murrieta, CA 92564

Insurance certificates also may be faxed to (888) 355-3599, or e-mailed to:
[email protected]

(3) The City may withdraw its offer of contract or cancel this Contract if the certificates of insurance and endorsements required have not been provided prior to execution of this Contract. The City may withhold payments to Contractor or cancel the Contract if the insurance is canceled or Contractor otherwise ceases to be insured as required herein.

F. Subcontractors

Contractors shall require and verify that all subcontractors maintain insurance coverage that meets the minimum scope and limits of insurance coverage specified in subsection A, above.

20. FAILURE TO MAINTAIN BONDS OR INSURANCE

If, at any time during the performance of this Contract, Contractor fails to maintain any item of the bonds and/or insurance required under the Contract in full force and effect, Contractor shall immediately suspend all work under the Contract and notify C ity in writing of such failure. After such notice is provided, or if City discovers such failure and notifies Contractor, the City thereafter may withhold all Contract payments due or that become due until notice is received by City that such bonds and/or insurance have been restored in full force and effect and that the premiums therefor have been paid for a period satisfactory to the Division of Risk Management. Contractor shall not resume work until notified by City to do so, and the City shall have no responsibility or liability for any costs incurred by Contractor as a result of such suspension of Work.

In addition to the foregoing, any failure to maintain any item of the required bonds and/or insurance at any time during the performance of this Contract will be sufficient cause for termination of the Contract by City.

Form approved by City Attorney 6-23-23 12

The Contractor shall be solely responsible for, and shall defend, indemnify, and hold harmless the City, its officers, employees and agents against and from, any and all damages, claims, losses, actions, costs or other expenses of any kind incurred by any party as a direct or indirect result of any suspension of Work or termination of the Contract under the provisions of this Section.

21. EXCUSABLE DELAYS

For the purpose of these Contract Documents, the term "Excusable Delay" shall mean, and is limited to, delay caused directly by : acts of God; acts of a public enemy; fires; inclement weather as determined by the Engineer; riots; insurrections; epidemics; quarantine restrictions; strikes; lockouts; sitdowns; acts of a governmental agency; priorities or privileges established for the manufacture, assemble, or allotment of materials necessary in the Work by order, decree or otherwise of the United States or by any department, bureau, commission, committee, agent, or administrator of any legally constituted public authority; changes in the Work ordered by City insofar as they necessarily require additional time in which to complete the Work; the prevention of Contractor from commencing or prosecuting the Work because of the acts of others, excepting Contractor's subcontractors or suppliers; or the prevention of Contractor from commencing or prosecuting the Work because of a Citywide failure of public utility service.

The term "Excusable Delay" shall specifically not include: (i) any delay that could have been avoided by the exercise of care, prudence, foresight and diligence on the part of Contractor; (ii) any delay in the prosecution of any part of the Work that does not constitute a Controlling Operation, whether or not such delay is unavoidable; (iii) any reasonable delay resulting from time required by City for review of any Contractor submittals and for the making of surveys, measurements and inspection; and, (iv) any delay arising from an interruption in the prosecution of the Work on account of reasonable interference by other Contractors employed by City that does not necessarily prevent the completion of the entire Work within the time specified. Excusable Delays, if any, shall operate only to extend the Completion Date (not in excess of the period of such delay as determined by City) and shall not under any circumstances increase the amount City is required to pay Contractor except as otherwise provided in these Contract Documents.

22. CONTRACTOR TO SERVE NOTICE OF DELAYS

Whenever Contractor foresees any delay in the prosecution of the Work, and in any event as soon as possible (not to exceed a period of ten (10) calendar days) after the initial occurrence of any delay that Contractor regards as or may later claim to be an Excusable Delay, the Contractor shall notify the Engineer in writing of such delay and its cause, in order that the Engineer : (i) may take immediate steps to prevent if possible the occurrence or continuance of the delay ; or (ii) if this cannot be done, may determine whether the delay is to be considered excusable, how long it continues, and to what extent the prosecution and completion of the Work are delayed thereby. Said written notice shall constitute an application for an extension of time only if the notice requests Form approved by City Attorney 6-23-23 13
such an extension and sets forth the Contractor's estimate of the additional time required together with a full description of the cause of the delay relied upon.

After the completion of any part or whole of the Work, the Engineer, in estimating the amount due Contractor, will assume that any and all delays that may have occurred in its prosecution and completion were not Excusable Delays, except for such delays for which the Contractor has provided timely written notice as required herein, and that the Engineer has found to be excusable. Contractor shall not be entitled to claim Excusable Delay for any delay for which the Contractor failed to provide such timely written notice.

23. EXTENSION OF TIME

If the Contractor complies with Section 22, above, and the Engineer finds a delay claimed by the Contractor to be an Excusable Delay, the Contractor shall be allowed an extension of time to complete the Work that is proportional to the period of Excusable Delay determined by the Engineer, subject to the approval by City of a change order granting such time extension. During a duly authorized extension for an Excusable Delay, City shall not charge liquidated damages against the Contractor for such delay.

If the City extends the time to complete the Work as provided herein, such extension shall in no way release any warranty or guarantee given by Contractor pursuant to the provisions of the Contract Documents, nor shall such extension of time relieve or release the sureties of the Bonds provided pursuant to the Contract Doc uments. By executing such Bonds, the Sureties shall be deemed to have expressly agreed to any such extension of time. The granting of any extension of time as provided herein shall in no way operate as a waiver on the part of City of its rights under this Contract, excepting only extension of the Completion Date for such period of Excusable Delay as may be determined by the Engineer and approved by a duly authorized change order.

24. NO PAYMENT FOR DELAYS

No damages or compensation of any kind shall be paid to Contractor or any subcontractor because of delays in the progress of the Work whether or not such delays qualify for extension of time under this Agreement; except that this provision shall not preclude the recovery of damages for a delay caused by the City that is unreasonable under the circumstances and that is not within the contemplation of the parties, provided that the Contractor timely submits all such written notice(s) and fully complies with such other procedures as may be specified in the Contract Documents or any Laws or Regulations for Contractor to claim damages for such delay.

25. CHANGES IN THE WORK

Changes in the Work authorized or directed in accordance with the Contract Documents and extensions of time of completion made necessary by reason thereof shall not in any way release any warranty or guarantee given by Contractor pursuant to the provisions of the Contract Documents, nor shall such changes in the Work relieve or release the Sureties on Bonds provided pursuant to the Contract Documents. By executing such Bonds, the Sureties shall be deemed to have expressly agreed to any such change in Work and to any extension of time made by reason thereof.

Form approved by City Attorney 6-23-23 14

26. TERMINATION AFTER COMPLETION DATE

In addition to any other rights City may have, if any services or work required under the Contract (including but not limited to punch list items) are not completed as of the Completion Date (as adjusted by any extensions of time for Excusable Delays granted pursuant to the Contract Documents), City may terminate the Contract at any time after the Completion Date ( as adjusted by any extensions of time for Excusable Delays granted pursuant to the Contract Documents ), by providing a written notice to Contrac tor specifying the date of termination. Such notice also may specify conditions or requirements that Contractor must meet to avoid termination of the Contract on such date. If Contractor fails to fulfill all such conditions and requirements by such termination date, or, if no such conditions or requirements are specified, Contractor shall cease rendering services and performing work on such termination date and shall not be entitled to receive any compensation for services rendered or work performed after such termination date. In the event of such termination, Contractor shall remain liable to City for liquidated damages incurred for any period of time prior to the termination date.

In addition to any other charges, withholdings or deductions authorized under the Contract or any Laws or Regulations, if City terminates the Contract pursuant to this section, City may withhold and deduct from any payment and/or retention funds otherwise due Contractor any sum necessary to pay the City's cost of completing or correcting, or contracting for the completion or correction of, any services or work under the Contract that are not completed to the satisfaction of the City or that otherwise are deficient or require correction as of such termination date, including but not limited to incomplete punch list items. Such costs shall include all of the City’s direct and indirect costs incurred to complete or correct such services or work, including the City’s administrative and overhead costs. If the amount of payment(s) and/or retention funds otherwise due the Contractor are insufficient to pay such costs, City shall have the right to recover the balance of such costs from the Contractor and/or its Surety(ies).

27. TERMINATION FOR CONVENIENCE

Upon written notice to the Contractor, the City may at any time, without cause and without prejudice to any other right or remedy of the City, elect to terminate the Contract for the convenience of City. In such case, the Contractor shall be paid (without duplication of any items, and after deduction and/or withholding of any amounts authorized to be deducted or withheld by the Contract Documents or any Law s or Regulations):

A. For Work executed in accordance with the Contract Documents prior to the effective date of termination and determined to be acceptable by the Engineer , including fair and reasonable sums for overhead and profit on such Work;

B. For reasonable claims, costs, losses, and damages incurred in settlement of terminated contracts with subcontractors, suppliers, and others; and

C. For reasonable expenses directly attributable to termination.

Form approved by City Attorney 6-23-23 15

Contractor shall not be paid for any loss of anticipated profits or revenue for any Work not performed prior to termination, nor for any economic loss arising out of or resulting from such termination, except for the payments listed in this section. Contractor’s warranty under Section 14 of this Agreement shall apply, and Contractor shall remain responsible for all obligations related to such warranty, with respect to all portions of the Work performed prior to the effective date of the termination for convenience pursuant to this section. The City shall be entitled to have any or all remaining Work performed by other contractors or by any other means at any time after the effective date of a termination for convenience pursuant to this section.

28. TERMINATION FOR BREACH OF CONTRACT

If Contractor abandons the Work under this Contract, or if the Contract or any portion of the Contract is sublet or assigned without the consent of the City, or if the Engineer determines in the Engineer’s sole discretion that the conditions of the Contract in respect to the rate of progress of the Work are not being fulfilled or any part thereof is unnecessarily delayed, or if Contractor violates or breaches, or fails to execute in good faith, any of the terms or conditions of the Contract, or if Contracto r refuses or fails to supply enough properly skilled labor or materials or refuses or fails to make prompt payment to subcontractors for material or labor, or if Contractor disregards any Laws or Regulations or proper instruction or orders of the Engineer, then, notwithstanding any provision to the contrary herein, the City may give Contractor and its Sureties written notification to immediately correct the situation or the Contract shall be terminated.

In the event that such notice is given, and, in the event such situation is not corrected, or arrangements for correction satisfactory to the City are not made, within ten (10) calendar days from the date of such notice or within such other period of time as may be specified by the City in the notice, the Contract shall upon the expiration of said period cease and terminate. In the event of any such termination, City may take over the Work and prosecute the Work to completion, or otherwise, and the Contractor and its Sureties shall be liable to City for any cost occasioned City thereby, as hereinafter set forth.

In the event City completes the Work, or causes the Work to be completed, no payment of any kind shall be made to Contractor until the Work is complete. The cost of completing the Work, including but not limited to, extra costs of project administration and management incurred by City, both direct or indirect, shall be deducted from any sum then due, or that becomes due, to Contractor from City. If sums due to Contractor from City are less than the cost of completing the Work, Contractor and its Sureties shall pay City a sum equal to this difference on demand. In the event City completes the Work, and there is a sum remaining due to Contractor after City deducts the costs of completing the Work, then City shall pay such sum to Contractor. The Contractor and Contractor’s Sureties shall be jointly and severally liable for all obligations imposed on Contractor hereunder.

No act by City before the Work is finally accepted, including, but not limited to, exercise of other rights under the Contract, actions at law or in equity, extensions of time, payments, assessments of liquidated damages, occupation or acceptance of any part of the Work, waiver of any prior breach of the Contract or failure to take action pursuant to Form approved by City Attorney 6-23-23 16
this section upon the happening of any prior default or breach of Contractor, shall be construed to be a waiver or esto ppel of the City’s right to act pursuant to this Section upon any subsequent event, occurrence or failure by Contractor to fulfill the terms and conditions of the Contract. The rights of City to terminate the Contract pursuant to this Section and pursuant to Sections 26 and 27 are cumulative and are in addition to all other rights of City pursuant to the Contract and at law or in equity.

29. CONTRACTOR BANKRUPT

If Contractor should commence any bankruptcy proceeding, or if Contractor is adjudged a bankrupt, or if Contractor makes any assignment for the benefit of creditors, or if a receiver is appointed on account of Contractor's insolvency, then the City may, without prejudice to any other right or remedy, terminate the Contract and complete the work by giving notice as provided in Section 28 above.

30. SURETIES’ OBLIGATIONS UPON TERMINATION

If the City terminates the Contract pursuant to Section 28 or Section 29 above:

A. The Surety under Contractor’s performance bond shall be fully responsible for all of the Contractor’s remaining obligations of performance under the Contract as if the Surety were a party to the Contract, including without limitation Contractor’s obligations, as provided in the Contract Documents, to complete and provide a one-year warranty of the entire Work , pay liquidated damages and indemnif y, defend and hold harmless City, up to the full amount of the performance bond.

B. The Surety under Contractor’s payment bond shall be fully responsible for the performance of all of the Contractor’s remaining payment obligations for work, services, equipment, or materials performed or provided in connection with the Work or any portion thereof, up to the full amount of the payment bond.

31. ACCOUNTING RECORDS OF CONTRACTOR

During performance of the Contract and f or a period of three (3) years after completing the entire Work, Contractor shall maintain all accounting and financial records related to the Contract and performance of the Work in accordance with generally accepted accounting practices and shall keep and make such records available for inspection and audit by representatives of the City upon reasonable written notice.

Form approved by City Attorney 6-23-23 17

32. USE TAX REQUIREMENTS

During the performance of this Agreement, CONTRACTOR, for itself, its assignees, and successors in interest, agrees as follows:

A. Use Tax Direct Payment Permit: For all leases and purchases of materials, equipment, supplies, or other tangible personal property used to perform the Agreement and shipped from outside California, the Contractor and any subcontractors leasing or purchasing such materials, equipment, supplies or other tangible personal property shall obtain a Use Tax Direct Payment Permit from the California State Board of Equalization (“SBE”) in accordance with the applicable SBE criteria and requirements.

B. Sellers Permit: For any construction contract and any construction subcontract in the amount of $5,000,000 or more, Contractor and the subcontractor(s) shall obtain sellers permits from the SBE and shall register the jobsite as the place of business for the purpose of allocating local sales and use tax to the City. Contractor and its subcontractors shall remit the self - accrued use tax to the SBE, and shall provide a copy of each remittance to the City.

C. The above provisions shall apply in all instances unless prohibited by the funding source for the Agreement.

33. NON-DISCRIMINATION IN EMPLOYEE BENEFITS

This Agreement may be subject to the requirements of Sacramento City Code Chapter

3.54, Non -Discrimination in Employee Benefits by City Contractors. The Contract Documents include a summary of the requirements of Sacramento City Code Chapter

3.54, entitled “Requirements of the Non- Discrimination in Employee Benefits Code.” By signing this Agreement, Contractor acknowledges and represents that Contractor has read and understands these requirements and agrees to fully comply with all applicable requirements of Sacramento City Code Chapter 3.54. If requested by City, Contractor agrees to promptly provide such documents and information as may be required by City to verify Contractor’s compliance. Any violation by Contractor of Sacramento City Code Chapter 3.54 constitutes a material breach of this Agreement, for which the City may terminate the Agreement and pursue all available legal and equitable remedies.

34. CONSIDERING CRIMINAL CONVICTION INFORMATION IN THE EMPLOYMENT

APPLICATION PROCESS

This Agreement may be subject to the requirements of Sacramento City Code Chapter

3.62, Procedures for Considering Criminal Conviction Information in the Employment Application Process. The Contract Documents include a summary of the requirements of Sacramento City Code Chapter 3.62, entitled “Ban- The-Box Requirements.” By signing this Agreement, Contractor acknowledges and represents Form approved by City Attorney 6-23-23 18
that Contractor has read and understands these requirements and agrees to fully comply with all applicable requirements of Sacramento City Code Chapter 3.62. If requested by City, Contractor agrees to promptly provide such documents and information as may be required by City to verify Contractor’s compliance. Any violation by Contractor of Sacramento City Code Chapter 3.62 constitutes a material breach of this Agreement, for which the City may terminate the Agreement and pursue all available legal and equ itable remedies. Contractor agrees to require its subcontractors to fully comply with all applicable requirements of Sacramento City Code Chapter 3.62 and include these requirements in all subcontracts covered by Sacramento City Code Chapter 3.62.

www.blackhawkpainting.com |Blackhawk Painting Inc. 821 Eubanks Dr. Ste A Vacaville, CA 95688 | Page 1 of 1

June 5, 2024

To: Wesley Rael Briggs
City of Sacramento | Department of Public Works
5730 24th Street, Building I, Sacramento, CA

Subject: Repainting Old Sacramento Parking Garage

Rael,

Below please find the intended scope of work for the project. Please let us know of any questions. Our bid includes pressure washing the exterior of the structure only to prep it for repainting. As per our conversation we would expect the entire interior to be pressure washed by the City of Sacramento. This would include washing of ceiling and sprinkler piping. Our proposal includes a two-tone paint job on masonry with a third color for metal railings & stair risers.

SCOPE OF WORK (Approx. location 125 I St Sacramento CA ) -Coordinate with City of Sacramento to establish work sequencing plan -Mobilize on site and begin pressure washing areas that are not cleaned by City (exterior walls elevations and structures) - Apply two coats Semi-Gloss Acrylic to parking garage ceilings, walls & columns ( exclude unpainted columns) -Apply two coats Gloss Urethane to metal hand railings, stair risers, elevator doors throughout structure. -Articulating manlifts and scissor lifts will be provided by Blackhawk Painting Inc. -Scaffolding for elevator tower and ceiling area in alcove at NW alcove to be provided by Blackhawk Painting Inc. - Estimated time to complete approx. 2 months

PRICE $542,500

EXCLUDE: Work not described in scope above.

Regards,

Joseph Hoberg
Project Manager | Estimator
AMPP Certified Coatings Inspector # N72484
Blackhawk Painting Inc. CA
821 Eubanks Dr Ste A, Vacaville, CA, 95688
Direct (707) 898-3811 | [email protected]
Lic. 765490 |DIR# 100020422 | SBE# 2006456

SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE

THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS.

INSURER(S) AFFORDING COVERAGE
INSURER F :

INSURER E :

INSURER D :

INSURER C :

INSURER B :

INSURER A :

NAIC #
NAME:

CONTACT
(A/C, No):

FAX
E-MAIL
ADDRESS:

PRODUCER
(A/C, No, Ext):

PHONE

INSURED
REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed.

If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).

THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS

CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.

OTHER:
(Per accident)
(Ea accident)
$
$
N / A
SUBR
WVD
ADDL
INSD

THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS

CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $ $
$
$PROPERTY DAMAGE
BODILY INJURY (Per accident)
BODILY INJURY (Per person)

COMBINED SINGLE LIMIT

AUTOS ONLY

AUTOSAUTOS ONLY

NON-OWNED

SCHEDULEDOWNED

ANY AUTO

AUTOMOBILE LIABILITY
Y / N

WORKERS COMPENSATION

AND EMPLOYERS' LIABILITY
OFFICER/MEMBER EXCLUDED?
(Mandatory in NH)
DESCRIPTION OF OPERATIONS below
If yes, describe under

ANY PROPRIETOR/PARTNER/EXECUTIVE
$
$
$
E.L. DISEASE - POLICY LIMIT
E.L. DISEASE - EA EMPLOYEE
E.L. EACH ACCIDENT
ER
OTH-

STATUTE
PER

LIMITS(MM/DD/YYYY)

POLICY EXP
(MM/DD/YYYY)

POLICY EFF

POLICY NUMBERTYPE OF INSURANCELTR
INSR
DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required)

EXCESS LIAB
UMBRELLA LIAB $EACH OCCURRENCE
$AGGREGATE
$
OCCUR

CLAIMS-MADE
DED RETENTION $
$PRODUCTS - COMP/OP AGG
$GENERAL AGGREGATE
$PERSONAL & ADV INJURY
$MED EXP (Any one person)
$EACH OCCURRENCE

DAMAGE TO RENTED
$PREMISES (Ea occurrence)

COMMERCIAL GENERAL LIABILITY

CLAIMS-MADE OCCUR
GEN'L AGGREGATE LIMIT APPLIES PER:

POLICY PRO-

JECT LOC

CERTIFICATE OF LIABILITY INSURANCE

DATE (MM/DD/YYYY)

CANCELLATION

AUTHORIZED REPRESENTATIVE
ACORD 25 (2016/03)
© 1988-2015 ACORD CORPORATION. All rights reserved.

CERTIFICATE HOLDER
The ACORD name and logo are registered marks of ACORD
HIRED

AUTOS ONLY
5/23/2024
InterWest Insurance Services, LLC
P.O. Box 8110
Chico CA 95927-8110
Valerie Cadile
916-797-4444
916-797-4444
[email protected]
License#: 0B01094
Starstone Nat'l Insurance Co
25496
BLACPAI-01
WCF Mutual Insurance Company
10033
Blackhawk Painting Co., Inc.
821 Eubanks Drive
Ste. A
Vacaville CA 95688
Accelerant Specialty Insurance Company
16890
2084188158
C
X
1,000,000
X
100,000
5,000
1,000,000
2,000,000
X
Y
Y
DACP000023500
5/23/2024
5/23/2025
2,000,000
A
X
5,000,000
X
82946T241ALI
5/23/2024
5/23/2025
5,000,000
B
X
Y
4037391
5/2/2024
5/2/2025
1,000,000
1,000,000
1,000,000
C
Pollution Liability
DACP000023500
5/23/2024
5/23/2025
Each Occurrence
General Aggregate
2,000,000
2,000,000
Workers' Compensation waiver of subrogation applies to requested entities if required by written contract per the attached policy form(s) /endorsement(s).

Additional Insured status applies to requested entities if required by written contract per the attached policy form/endorsement(s). Waiver of subrogation applies to requested entities if required by written contract per the attached policy form/endorsement(s). Primary non-contributory applies to requested entities if required by written contract per the attached policy form/endorsement(s).

City of Sacramento
Department of Public Works,
Facilities Maintenance Division
5730 24th Street, Bldg 4
Sacramento CA 95822

CG 20 10 04 13
© Insurance Services Office, Inc., 2012

Page 1 of 2 ends

POLICY NUMBER: DACP0000235-00

COMMERCIAL GENERAL LIABILITY
CG 20 10 04 13

THIS ENDORSEMENT CHANGES TH
E POLICY. PL

EASE RE
AD IT
CAREFULLY.

ADDITIONAL INSURED – OWNERS, LESSEES OR
CONTRACTORS – SCHEDULED PERSON OR

ORGANIZATION
This endorsement modifies insurance provided under the following:

COMMERCIAL GENERAL LIABILITY COVERAGE PART

SCHEDULE
Name Of Additional Insured Person(s)
Or Organization(s)
Location(s) Of Covered Operations
Any person or organization for whom you are performing
operations when you and such person or organization have agreed in writing in a contract or agreement, effected prior to the date your operations for that person or organization commenced, that such person or organization be added as an additional insured on your policy
In respect to any location where the named insured is
performing “your work”.

Information required to complete this Schedule, if
not shown above, will be
shown in t
he Decla
rations.

1. Your acts or omissions; or

2. The acts or omissions of those acting on your
behalf;
in the performance of your ongoing operations for
the additional insured(s) at the location(s)
designated above.

However:

1. The insurance afforded to such additional
insured only applies to the extent permitted by
law; and

2. If coverage provided to the additional insured is
required by a contract or agreement, the
insurance afforded to such additional insured
will not be broader than that which you are
required by the contract or agreement to provide
for such additional insured.

With respect to the insurance afforded to these
additional insureds, the following additional
exclusions apply:

This insurance does not apply to "bodily injury" or
"property damage" occurring after:

1. All work, including materials, parts or equipment
furnished in connection with such work, on the
project (other than service, maintenance or
repairs) to be performed by or on behalf of the
additional insured(s) at the location of the
covered operations has been completed; or

2. That portion of "your work" out of which the
injury or damage arises has been put to its
intended use by any person or organization
other than another contractor or subcontractor
engaged in performing operations for a principal
as a part of the same project.

Page 2 of 2 ends

With respect to the insurance afforded to these
additional insureds, the following is added to
Section III – Limits Of Insurance:

If coverage provided to the additional insured is
required by a contract or agreement, the most we
will pay on behalf of the additional insured is the
amount of insurance:

1. Required by the contract or agreement; or

2. Available under the applicable Limits of
Insurance shown in the Declarations;
whichever is less.

This endorsement shall not increase the applicable
Limits of Insurance
shown in the
Declarations.

POLICY NUMBER: DACP0000235-00

COMMERCIAL GENERAL LIABILITY
CG 20 37 04 13

THIS ENDORSEMENT CHANGES TH
E POLICY. PL

EASE RE
AD IT
CAREFULLY.

ADDITIONAL INSURED – OWNERS, LESSEES OR
CONTRACTORS – COMPLETED OPERATIONS
This endorsement modifies insurance provided under the following:

COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED

OPERATIONS LIABILITY COVERAGE PART

SCHEDULE
Name Of Additional Insured Person(s)
Or Organization(s)
Location And Description Of
Completed Operations
Any person or organization for whom you are performing
operations when you and such person or organization have agreed in writing in a contract or agreement, effected prior to the date your operations for that person or organization commenced, that such person or organization be added as an additional insured on your policy
In respect to any location where the named insured is
performing “your work”.

Information required to complete this Schedule, if
not shown above, will be
shown in th
e Declarations.

A. Section II – Who Is An Insured
is amended to
include as an additional insured the person(s) or
organization(s) shown in the Schedule, but only
with respect to liability for "bodily injury" or
"property damage" caused, in whole or in part, by
"your work" at the location designated and
described in the Schedule of this endorsement
performed for that additional insured and included
in the "products-complet
ed operations
hazard".

However:

1. The insurance afforded to such additional
insured only applies to the extent permitted by
law; and

2. If coverage provided to the additional insured
is required by a contract or agreement, the
insurance afforded to such additional insured
will not be broader than that which you are
required by the contract or agreement to
provide for such additional insured.

With respect to the insurance afforded to these
additional insureds, the following is added to
Section
III – Limits Of Insurance:

If coverage provided to the additional insured is
required by a contract or agreement, the most we will
pay on behalf of the additional insured is the amount
of insurance:

1. Required by the contract or agreement; or

2. Available under the applicable Limits of
Insurance shown in the Declarations;
whichever is less.

This endorsement shall not increase the applicable
Limits of Insurance shown in the Declarations.

Page 1 of 1 ends

Includes copyrighted material of Insurance Services
Office, Inc. with its permission

Page 1 of 2 ends

Designated Construction Projects:

Each project for which you have agreed, in a written contract which is in effect during the policy period, to provide a separate general aggregate limit, provided that the contract is signed and executed prior to any loss for which coverage is sought.

POLICY NUMBER: DACP0000235-00 COMMERCIAL GENERAL LIABILITY DACP 25 03 11 23
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.

DESIGNATED CONSTRUCTION PROJECT(S)

GENERAL AGGREGATE LIMIT WITH CAP
This endorsement modifies insurance provided under the following:

COMMERCIAL GENERAL LIABILITY COVERAGE PART

SCHEDULE
(If no entry appears above, information required to complete this endorsement will be shown in the Declarations as applicable to this endorsement.)
A. For all sums which the insured becomes legally
obligated to pay as damages caused by
“occurrences” under COVERAGE A (SECTION I),
and for all medical expenses caused by acci-
dents under COVERAGE C (SECTION I), which
can be attributed only to ongoing operations at a
single designated construction project shown in
the Schedule above:

1. A separate Designated Construction Project
General Aggregate Limit applies to each
designated construction project, and that limit
is equal to the amount of the Aggregate Limit
(Coverages A,B,C) shown in the Declarations.

2. The Designated Construction Project General
Aggregate Limit is the most we will pay for the
sum of all damages under COVERAGE A,
except damages because of “bodily injury” or
“property damage” included in the “products-
completed operations hazard”, and for medical
expenses under COVERAGE C regardless of
the number of:
a. Insureds;
b. Claims made or “suits” brought; or
c. Persons or organizations making claims or
bringing “suits”.

3. Any payments made under COVERAGE A for
damages or under COVERAGE C for medical
expenses shall reduce the Designated
Construction Project General Aggregate Limit
for that designated construction project. Such
payments shall not reduce the Aggregate Limit
(Coverages A,B,C) shown in the Declarations
nor shall they reduce any other Designated
Construction Project General Aggregate Limit
for any other designated construction project
shown in the Schedule above.

4. The limits shown in the Declarations for Each
Occurrence and Medical Expense continue to
apply. However, instead of being subject to the
Aggregate Limit (Coverages A,B,C) shown in
the Declarations, such limits will be subject to
the applicable Designated Construction
Project General Aggregate Limit.

5. The most we will pay for the sum of all
Designated Construction Project General
Aggregate Limits combined to which this
insurance applies is $5,000,000.00.

B. For all sums which the insured becomes legally
obligated to pay as damages caused by
“occurrences” under COVERAGE A (SECTION I),
and for all medical expenses caused by acci-
dents under COVERAGE C (SECTION I), which
cannot be attributed only to ongoing operations at
a single designated construction project shown in
the Schedule above:

1. Any payments made under COVERAGE A for
damages or under COVERAGE C for medical
expenses shall reduce the amount available
under the Aggregate Limit (Coverages A,B,C)
or the Products-Completed Operations
Aggregate Limit, whichever is applicable; and

2. Such payments shall not reduce any Desig-
nated Construction Project General Aggre-
gate Limit.

C. When coverage for liability arising out of the
“products-completed operations hazard” is pro-
vided, any payments for damages because of
“bodily injury” or “property damage” included in the
“products-completed operations hazard” will
reduce the Products-Completed Operations Ag-
gregate Limit, and not reduce the Aggregate Limit
(Coverages A,B,C) nor the Designated
Construction Project General Aggregate Limit.

Includes copyrighted material of Insurance Services
Office, Inc. with its permission Page 2 of 2DACP 25 03 11 23 D. If the applicable designated construction project
has been abandoned, delayed, or abandoned and
then restarted, or if the authorized contracting
parties deviate from plans, blueprints, designs,
specifications or timetables, the project will still be deemed to be the same construction project.

E. The provisions of Limits Of Insurance (SECTION
III) not otherwise modified by this endorsement
shall continue to apply as stipulated.

DACP 02 09 11 23
Includes copyrighted material of Insurance Services Office, Inc.

Page 1 of 1 ends

with its permission
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.

PRIMARY/NON-CONTRIBUTORY COVERAGE

NAMED PERSON OR ORGANIZATION
This endorsement modifies insurance provided under the following:

COMMERCIAL GENERAL LIABILITY COVERAGE PART
PRIMARY/NON-CONTRIBUTORY – If required by written contract or agreement, effective prior to the date your operations for that person or organization commenced and named below, such insurance as is afforded by this policy to any additional insureds under this policy shall be primary insurance, and any insurance or self-insurance maintained by such additional insured(s) shall not contribute to the insurance afforded to the named insured.

All other terms and conditions remain unchanged.

SCHEDULE
Any person or organization that is:

1. An owner of real or personal property on which you are performing operations, but only at the specific written request by that person or organization to you, and only if:
a. That request is made prior to the date your operations for that person or organization commenced; and
b. A Certificate of Insurance evidencing that request has been issued by your authorized insurance agent or broker; or

2. A contractor on whose behalf you are performing operations, but only at the specific written request by that person or organization to you, and only if:
a. That request is made prior to the date your operations for that person or organization commenced; and
b. A Certificate of Insurance evidencing that request has been issued by your authorized insurance agent or broker.

Information required to complete this Schedule, if
not shown above, will be
shown in
the D
eclarations.

Name Of Person(
s) Or
Organization(s):

A
ny person or organization for whom you are performing operations when you and such person or organization have agreed in writing in a contract or agreement, effected prior to the date your operations for that person or organization commenced, that such person or organization be added as an additional insured on your policy.

In respect to any location where the named insured is performing “your work”.

POLICY NUMBER: DACP0000235-00

COMMERCIAL GENERAL LIABILITY
CG 24 04 12 19

THIS ENDORSEMENT CHANGES TH
E POLICY. PL

EASE RE
AD IT
CAREFULLY.

WAIVER OF TRANSFER OF RIGHTS OF RECOVERY

AGAINST OTHERS TO US (WAIVER OF SUBROGATION)
This endorsement modifies insurance provided under the following:

COMMERCIAL GENERAL LIABILITY COVERAGE PART

ELECTRONIC DATA LIABILITY COVERAGE PART

LIQUOR LIABILITY COVERAGE PART

POLLUTION LIABILITY COVERAGE PART DESIGNATED SITES

POLLUTION LIABILITY LIMITED COVERAGE PART DESIGNATED SITES

PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART

RAILROAD PROTECTIVE LIABILITY COVERAGE PART

UNDERGROUND STORAGE TANK POLICY DESIGNATED TANKS

SCHEDULE
The following is added to Paragraph

8. Transfer Of
Rights Of Recovery Against Others To Us
of
Section IV – Conditions:

We waive any right of recovery against the person(s)
or organization(s) shown in the Schedule above
because of payments we make under this Coverage
Part. Such waiver by us applies only to the extent that the insured has waived its right of recovery against
such person(s) or organization(s) prior to loss. This
endorsement applies only to the person(s) or
organization(s) shown in the Schedule above.

Page 1 of 1 ends

WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 00 03 13 (Ed. 4-84)
Policy No. 4037391
This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated.

Insured Black Hawk Painting Co Inc
Endorsement No.

Premium
Endorsement Effective 05/02/2024
821 Eubanks Dr Ste A
Vacaville, CA 95688-9356
WCF National Insurance CompanyInsurance Company
Countersigned by

WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT
We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule.

Schedule

1. Waiver Type Blanket
A blanket waiver of subrogation is granted for all projects and contracts for the below named insured and its subsidiaries for all jobs requiring such a waiver in writing in all states excluding Texas listed under section 3A of your information page.

Sacramento City CouncilSeptember 10, 2024

Sacramento City Council
September 10, 2024