55452.01510\32977834.2
1 CITY OF SAN CLEMENTE
CONSTRUCTION CONTRACT
RICHARD T. STEED PARK SLOPE EROSION REPAIRS
1. PARTIES AND DATE.
This Contract is made and entered into this ____ day of _________, 2023 by and between the City of San Clemente, a public agency of the State of California (“City”) and O’Connell Engineering & Construction, Inc., (“Contractor”). City and Contractor are sometimes individually referred to as “Party” and collectively as “Parties” in this Contract.
2. RECITALS.
2.1 City. City is a public agency organized under the laws of the State of California, with power to contract for services necessary to achieve its purpose.
2.2 Contractor. Contractor desires to perform and assume responsibility for the provision of certain construction services required by the City on the terms and conditions set forth in this Contract. Contractor represents that it is duly licensed and experienced in providing RICHARD T. STEED PARK SLOPE EROSION REPAIRS related construction services to public clients, that it and its employees or subcontractors have all necessary licenses and permits to perform the services in the State of California, and that it is familiar with the plans of City. The following license classifications are required for this Project: California Contract License Class A.
2.3 Project. City desires to engage Contractor to render such services for the RICHARD T. STEED PARK SLOPE EROSION REPAIRS (“Project”) as set forth in this Contract.
2.4 Project Documents & Certifications. Contractor has obtained, and delivers concurrently herewith, a performance bond, a payment bond, and all insurance documentation, as required by the Contract.
3. TERMS
3.1 Incorporation of Documents. This Contract includes and hereby incorporates in full by reference the following documents, including all exhibits, drawings, specifications and documents therein, and attachments and addenda thereto:
x Services/Schedule (Exhibit “A”)
x Plans and Specifications (Exhibit “B”)
x Special Conditions (Exhibit “C”)
x Contractor’s Certificate Regarding Workers’ Compensation (Exhibit “D”) x Public Works Contractor Registration Certification (Exhibit “E”) x Payment and Performance Bonds (Exhibit “F”)
x Federal Requirements (Exhibit “G”) (Not Applicable)
x Insurance Requirements (Exhibit “H)
x Addenda
x Change Orders executed by the City
x 2021 Edition of the Standard Specifications for Public Works Construction (The Greenbook), Excluding Sections 1-8
$WWDFKPHQW2
DRAFThe laws he la
purpose. purpo
rform and assume re rform and assu
by theCity on the term he te
t is duly licensed and e
REPAIRS related con re
tractors have all neces tractors have a
ornia, and that nia, and itis fam
uired for this Project: Ca for this Project: C
res to engage Contra res to engage
OPE EROSION OPE EROS REPAI
cuments & Certificatio nts & Certificatio DR
a performance bond, a a performance b
ontract. ontrac
n of DoDg
55452.01510\32977834.2
2 x Notice Inviting Bids, if any
x Instructions to Bidders, if any
x Contractor’s Bid
3.2 Contractor’s Basic Obligation; Scope of Work. Contractor promises and agrees, at its own cost and expense, to furnish to the City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately complete the Project, including all structures and facilities necessary for the Project or described in the Contract (hereinafter sometimes referred to as the “Work”), for a Total Contract Price as specified pursuant to this Contract. All Work shall be subject to, and performed in accordance with the above referenced documents, as well as the exhibits attached hereto and incorporated herein by reference. The plans and specifications for the Work are further described in Exhibit “B” attached hereto and incorporated herein by this reference. Special Conditions, if any, relating to the Work are described in Exhibit “C” attached hereto and incorporated herein by this reference.
3.2.1 Change in Scope of Work. Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition or deletion is approved in writing by a valid change order executed by the City. Should Contractor request a change order due to unforeseen circumstances affecting the performance of the Work, such request shall be made within five (5) business days of the date such circumstances are discovered or shall waive its right to request a change order due to such circumstances. If the Parties cannot agree on any change in price required by such change in the Work, the City may direct the Contractor to proceed with the performance of the change on a time and materials basis.
3.2.2 Substitutions/“Or Equal”. Pursuant to Public Contract Code Section 3400(b), the City may make a finding that designates certain products, things, or services by specific brand or trade name. Unless specifically designated in this Contract, whenever any material, process, or article is indicated or specified by grade, patent, or proprietary name or by name of manufacturer, such Specifications shall be deemed to be used for the purpose of facilitating the description of the material, process or article desired and shall be deemed to be followed by the words “or equal.”
Contractor may, unless otherwise stated, offer for substitution any material, process or article which shall be substantially equal or better in every respect to that so indicated or specified in this Contract. However, the City may have adopted certain uniform standards for certain materials, processes and articles. Contractor shall submit requests, together with substantiating data, for substitution of any “or equal” material, process or article no later than thirty-five (35) days after award of the Contract. To facilitate the construction schedule and sequencing, some requests may need to be submitted before thirty-five (35) days after award of Contract. Provisions regarding submission of “or equal” requests shall not in any way authorize an extension of time for performance of this Contract. If a proposed “or equal” substitution request is rejected, Contractor shall be responsible for providing the specified material, process or article.
The burden of proof as to the equality of any material, process or article shall rest with Contractor.
The City has the complete and sole discretion to determine if a material, process or article is an “or equal” material, process or article that may be substituted. Data required to substantiate requests for substitutions of an “or equal” material, process or article data shall include a signed affidavit from Contractor stating that, and describing how, the substituted “or equal” material, process or article is equivalent to that specified in every way except as listed on DRAFTin the s in th
other matter other
accepted unless s accepted u
er executed by the er executed by the City
ances affecting the perf ances affecting the pe
ness days of the date ess days of the date
a change order due to s nge orde
e required by such chan e required by su
e performance of the c performance of the
ns/“Or Equal”. Pursu ns/“Or Equal”. RA
finding that designate finding that design
me. Unless specifically Unless specifically
e is indicated or specif
, such Specifications , such Specificat
ption of the material, p ption of the material,
ds “or equal.” ds “or
r may, un
ll be s
55452.01510\32977834.2
3 the affidavit. Substantiating data shall include any and all illustrations, specifications, and other relevant data including catalog information which describes the requested substituted “or equal” material, process or article, and substantiates that it is an “or equal” to the material, process or article. The substantiating data must also include information regarding the durability and lifecycle cost of the requested substituted “or equal” material, process or article. Failure to submit all the required substantiating data, including the signed affidavit, to the City in a timely fashion will result in the rejection of the proposed substitution.
Contractor shall bear all of the City’s costs associated with the review of substitution requests. Contractor shall be responsible for all costs related to a substituted “or equal” material, process or article. Contractor is directed to the Special Conditions (if any) to review any findings made pursuant to Public Contract Code section 3400.
3.3 Period of Performance.
3.3.1 Contract Time. Contractor shall perform and complete all Work under this Contract within Ten (10) working days, beginning the effective date of the Notice to Proceed (“Contract Time”). Contractor shall perform its Work in strict accordance with any completion schedule, construction schedule or project milestones developed by the City. Such schedules or milestones may be included as part of Exhibits “A” or “B” attached hereto, or may be provided separately in writing to Contractor. Contractor agrees that if such Work is not completed within the aforementioned Contract Time and/or pursuant to any such completion schedule, construction schedule or project milestones developed pursuant to provisions of the Contract, it is understood, acknowledged and agreed that the City will suffer damage.
3.3.2 Force Majeure. Neither City nor Contractor shall be considered in default of this Contract for delays in performance caused by circumstances beyond the reasonable control of the non-performing party. For purposes of this Contract, such circumstances include but are not limited to, abnormal weather conditions; floods; earthquakes; fire; pandemics or epidemics; war; riots and other civil disturbances; strikes, lockouts, work slowdowns, and other labor disturbances; sabotage or judicial restraint. Should such circumstances occur, the nonperforming party shall, within a reasonable time of being prevented from performing, give written notice to the other party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Contract. Contractor’s exclusive remedy in the event of delay covered under this section shall be a non-compensable extension of the Contract Time.
3.3.3 Liquidated Damages. Pursuant to Government Code Section 53069.85, Contractor shall pay to the City as fixed and liquidated damages the sum of Eight Hundred Dollars ($800) per day for each and every calendar day of delay beyond the Contract Time or beyond any completion schedule, construction schedule or Project milestones established pursuant to the Contract.
3.4 Standard of Performance; Performance of Employees. Contractor shall perform all Work under this Contract in a skillful and workmanlike manner, and consistent with the standards generally recognized as being employed by professionals in the same discipline in the State of California. Contractor represents and maintains that it is skilled in the professional calling necessary to perform the Work. Contractor warrants that all employees and subcontractors shall have sufficient skill and experience to perform the Work assigned to them. Finally, Contractor represents that it, its employees and subcontractors have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Work, including any required DRAFTand co
ctive date o ctive
strict accordance strict acco
developed by the developed by the City.
or “B” attached hereto or “B” attached here
grees that if such Work rees that if such Work
ant to any such comple to any suc
rsuant to provisions of t rsuant to provi
ll suffer damage. suffer damage.
. Neither City nor Con Neither City nor Con
rformance caused by rformance cause
arty. For purposes of t arty. For purposes
rmal weather condition mal weather conditio
other civil disturbances civil disturbances
otage or judicial restra otage or judicia
l, within a reasonable t l, within a reasonable
arty describing the cir
resume performa resume perform
nder this se
55452.01510\32977834.2
4 business license, and that such licenses and approvals shall be maintained throughout the term of this Contract. As provided for in the indemnification provisions of this Contract, Contractor shall perform, at its own cost and expense and without reimbursement from the City, any work necessary to correct errors or omissions which are caused by Contractor’s failure to comply with the standard of care provided for herein. Any employee who is determined by the City to be uncooperative, incompetent, a threat to the safety of persons or the Work, or any employee who fails or refuses to perform the Work in a manner acceptable to the City, shall be promptly removed from the Project by Contractor and shall not be re-employed on the Work.
3.5 Control and Payment of Subordinates; Contractual Relationship. City retains Contractor on an independent contractor basis and Contractor is not an employee of City. Any additional personnel performing the work governed by this Contract on behalf of Contractor shall at all times be under Contractor’s exclusive direction and control. Contractor shall pay all wages, salaries, and other amounts due such personnel in connection with their performance under this Contract and as required by law. Contractor shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, and workers’ compensation insurance.
3.6 City’s Basic Obligation. City agrees to engage and does hereby engage Contractor as an independent contractor to furnish all materials and to perform all Work according to the terms and conditions herein contained for the sum set forth above. Except as otherwise provided in the Contract, the City shall pay to Contractor, as full consideration for the satisfactory performance by Contractor of the services and obligations required by this Contract, the belowreferenced compensation in accordance with compensation provisions set forth in the Contract.
3.7 Compensation and Payment.
3.7.1 Amount of Compensation. As consideration for performance of the Work required herein, City agrees to pay Contractor the Total Contract Price of Ninety Eight Thousand Four Hundred and Sixty Dollars ($98,460.00) (“Total Contract Price”) provided that such amount shall be subject to adjustment pursuant to the applicable terms of this Contract or written change orders approved and signed in advance by the City.
3.7.2 Payment of Compensation. If the Work is scheduled for completion in Thirty (30) or less calendar days, City will arrange for payment of the Total Contract Price upon completion and approval by City of the Work. If the Work is scheduled for completion in more than thirty (30) calendar days, City will pay Contractor on a monthly basis as provided for herein.
On or before the fifth (5th) day of each month, Contractor shall submit to the City an itemized application for payment in the format supplied by the City indicating the amount of Work completed since commencement of the Work or since the last progress payment. These applications shall be supported by evidence which is required by this Contract and such other documentation as the City may require. The Contractor shall certify that the Work for which payment is requested has been done and that the materials listed are stored where indicated. Contractor may be required to furnish a detailed schedule of values upon request of the City and in such detail and form as the City shall request, showing the quantities, unit prices, overhead, profit, and all other expenses involved in order to provide a basis for determining the amount of progress payments.
3.7.3 Prompt Payment. City shall review and pay all progress payment requests in accordance with the provisions set forth in Section 20104.50 of the California Public Contract Code. However, no progress payments will be made for Work not completed in accordance with DRAFTe f
d to: soc d to:
mpensation in mpensa
to engage and do to engage an
l materials and to perfo l materials and to perf
the sum set forth abov he sum set forth abov
ontractor, as full consid actor, as f
nd obligations required nd obligations
with compensation prov th compensation p
ayment.
RA
of Compensation. As c of Compensation. A
o payContractor the T
ollars ($98,460 00 . ) (“To
stment pursuant to the a stment pursuant
signed in advance by t signed in advance by
Payment of Com Payment of C
dar days, DCi
y City
C
55452.01510\32977834.2
5 this Contract. Contractor shall comply with all applicable laws, rules and regulations relating to the proper payment of its employees, subcontractors, suppliers or others.
3.7.4 Contract Retentions. From each approved progress estimate, five percent (5%) will be deducted and retained by the City, and the remainder will be paid to Contractor. All Contract retention shall be released and paid to Contractor and subcontractors pursuant to California Public Contract Code Section 7107.
3.7.5 Other Retentions. In addition to Contract retentions, the City may deduct from each progress payment an amount necessary to protect City from loss because of: (1) liquidated damages which have accrued as of the date of the application for payment; (2) any sums expended by the City in performing any of Contractor’s obligations under the Contract which Contractor has failed to perform or has performed inadequately; (3) defective Work not remedied; (4) stop notices as allowed by state law; (5) reasonable doubt that the Work can be completed for the unpaid balance of the Total Contract Price or within the scheduled completion date; (6) unsatisfactory prosecution of the Work by Contractor; (7) unauthorized deviations from the Contract; (8) failure of Contractor to maintain or submit on a timely basis proper and sufficient documentation as required by the Contract or by City during the prosecution of the Work; (9) erroneous or false estimates by Contractor of the value of the Work performed; (10) any sums representing expenses, losses, or damages as determined by the City, incurred by the City for which Contractor is liable under the Contract; and (11) any other sums which the City is entitled to recover from Contractor under the terms of the Contract or pursuant to state law, including Section 1727 of the California Labor Code. The failure by the City to deduct any of these sums from a progress payment shall not constitute a waiver of the City’s right to such sums.
3.7.6 Substitutions for Contract Retentions. In accordance with California Public Contract Code Section 22300, the City will permit the substitution of securities for any monies withheld by the City to ensure performance under the Contract. At the request and expense of Contractor, securities equivalent to the amount withheld shall be deposited with the City, or with a state or federally chartered bank in California as the escrow agent, and thereafter the City shall then pay such monies to Contractor as they come due. Upon satisfactory completion of the Contract, the securities shall be returned to Contractor. For purposes of this Section and Section 22300 of the Public Contract Code, the term “satisfactory completion of the contract” shall mean the time the City has issued written final acceptance of the Work and filed a Notice of Completion as required by law and provisions of this Contract. Contractor shall be the beneficial owner of any securities substituted for monies withheld and shall receive any interest thereon. The escrow agreement used for the purposes of this Section shall be in the form provided by the City.
3.7.7 Title to Work. As security for partial, progress, or other payments, title to Work for which such payments are made shall pass to the City at the time of payment. To the extent that title has not previously been vested in the City by reason of payments, full title shall pass to the City at delivery of the Work at the destination and time specified in this Contract. Such transferred title shall in each case be good, free and clear from any and all security interests, liens, or other encumbrances. Contractor promises and agrees that it will not pledge, hypothecate, or otherwise encumber the items in any manner that would result in any lien, security interest, charge, or claim upon or against said items. Such transfer of title shall not imply acceptance by the City, nor relieve Contractor from the responsibility to strictly comply with the Contract, and shall not relieve Contractor of responsibility for any loss of or damage to items.
DRAFTch
unautho unaut
a timely bas a tim
uring the prosecu uring the p
ue of the Work perform ue of the Work p
ermined by the ermin City, inc
d (11) any other sums w (11) any other sums w
the Contract or pursu Contract
The failure by the The failure by City
ute a waiver of the e a waiver of the City
or Contract Retentions. act Retentions. RA
e City will permit the s will permit
performance under the performance under
lent to the amount with nt to the amount with
ed bank in California as nk in California as
to Contractor as they to Contractor as
es shall be returned to C es shall be returned to
Contract Code, the te
ssued written fina ssued written fi
provisions o
or mon
55452.01510\32977834.2
6 3.7.8 Labor and Material Releases. Contractor shall furnish City with labor and material releases from all subcontractors performing work on, or furnishing materials for, the Work governed by this Contract prior to final payment by City.
3.7.9 Prevailing Wages. Contractor is aware of the requirements of California Labor Code Section 1720 et seq., and 1770 et seq., as well as California Code of Regulations, Title 8, Section 16000 et seq., (“Prevailing Wage Laws”), which require the payment of prevailing wage rates and the performance of other requirements on “public works” and “maintenance” projects. Since the Services are being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and since the total compensation is $1,000 or more, Contractor agrees to fully comply with such Prevailing Wage Laws. City shall provide Contractor with a copy of the prevailing rates of per diem wages in effect at the commencement of this Contract upon request. Contractor shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services available to interested parties upon request, and shall post copies at Contractor’s principal place of business and at the project site. Contractor shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws. Contractor and any subcontractor shall forfeit a penalty of up to $200 per calendar day or portion thereof for each worker paid less than the prevailing wage rates.
3.7.10 Apprenticeable Crafts. When Contractor employs workmen in an apprenticeable craft or trade, Contractor shall comply with the provisions of Section 1777.5 of the California Labor Code with respect to the employment of properly registered apprentices upon public works. The primary responsibility for compliance with said section for all apprenticeable occupations shall be with Contractor. The Contractor or any subcontractor that is determined by the Labor Commissioner to have knowingly violated Section 1777.5 shall forfeit as a civil penalty an amount not exceeding $100 for each full calendar day of noncompliance, or such greater amount as provided by law.
3.7.11 Hours of Work. Contractor is advised that eight (8) hours labor constitutes a legal day’s work. Pursuant to Section 1813 of the California Labor Code, Contractor shall forfeit a penalty of $25.00 per worker for each day that each worker is permitted to work more than eight (8) hours in any one calendar day and forty (40) hours in any one calendar week, except when payment for overtime is made at not less than one and one-half (1-1/2) times the basic rate for that worker.
3.7.12 Payroll Records. Contractor and each subcontractor shall keep an accurate payroll record, showing the name, address, social security number, work classification, straight time and overtime hours worked each day and week, and the actual per diem wages paid to each journeyman, apprentice, worker, or other employee employed by him or her in connection with the public work. The payroll records shall be certified and shall be available for inspection at all reasonable hours at the principal office of Contractor in the manner provided in Labor Code section 1776. In the event of noncompliance with the requirements of this section, Contractor shall have 10 days in which to comply subsequent to receipt of written notice specifying in what respects such Contractor must comply with this section. Should noncompliance still be evident after such 10-day period, Contractor shall, as a penalty to City, forfeit not more than $100.00 for each calendar day or portion thereof, for each worker, until strict compliance is effectuated. The amount of the forfeiture is to be determined by the Labor Commissioner. A contractor who is found to have violated the provisions of law regarding wages on Public Works with the intent to defraud shall be ineligible to bid on Public Works contracts for a period of one to three years as DRAFTall
shall d shal
d harmless fr d harm
the Prevailing Wa he Prevail
200 per calendar day o 200 per calendar
s.
When Contractor e When Con
l comply with the provis l comply with t
e employment of prope employment of pro
ty for compliance with compliance with
. The Contractor or any The Contractor or any
knowingly violated Sect knowingly violate
0 for each full calenda 0 for each full calen
ours of Work. Contrac C DR
ursuant to Section 1813 ursuant to Section 18
per worker for each da
calendar day and calendar day a
made at no
55452.01510\32977834.2
7 determined by the Labor Commissioner. Upon the request of the Division of Apprenticeship Standards or the Division of Labor Standards Enforcement, such penalties shall be withheld from progress payments then due. The responsibility for compliance with this section is on Contractor.
The requirement to submit certified payroll records directly to the Labor Commissioner under Labor Code section 1771.4 shall not apply to work performed on a public works project that is exempt pursuant to the small project exemption specified in Labor Code Section 1771.4.
3.7.13 Contractor and Subcontractor Registration. Pursuant to Labor Code sections 1725.5 and 1771.1, all contractors and subcontractors that wish to bid on, be listed in a bid proposal, or enter into a contract to perform public work must be registered with the Department of Industrial Relations. No bid will be accepted nor any contract entered into without proof of the contractor’s and subcontractors’ current registration with the Department of Industrial Relations to perform public work. Contractor is directed to review, fill out and execute the Public Works Contractor Registration Certification attached hereto as Exhibit “E” prior to contract execution. Notwithstanding the foregoing, the contractor registration requirements mandated by Labor Code Sections 1725.5 and 1771.1 shall not apply to work performed on a public works project that is exempt pursuant to the small project exemption specified in Labor Code Sections 1725.5 and 1771.1.
3.7.14 Labor Compliance; Stop Orders. This Project is subject to compliance monitoring and enforcement by the Department of Industrial Relations. It shall be the Contractor’s sole responsibility to evaluate and pay the cost of complying with all labor compliance requirements under this Contract and applicable law. Any stop orders issued by the Department of Industrial Relations against Contractor or any subcontractor that affect Contractor’s performance of Work, including any delay, shall be Contractor’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Contractor caused delay subject to any applicable liquidated damages and shall not be compensable by the City.
Contractor shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the Department of Industrial Relations against Contractor or any subcontractor.
3.8 Performance of Work; Jobsite Obligations.
3.8.1 Water Quality Management and Compliance.
3.8.1.1 Water Quality Management and Compliance. Contractor shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Work including, without limitation, all applicable provisions of the Federal Water Pollution Control Act (33 U.S.C. §§ 1300); the California Porter-Cologne Water Quality Control Act (Cal Water Code §§ 13000-14950); local ordinances regulating discharges of storm water; and any and all regulations, policies, or permits issued pursuant to any such authority regulating the discharge of pollutants, as that term is used in the Porter-Cologne Water Quality Control Act, to any ground or surface water in the State.
3.8.1.2 Compliance with the Statewide Construction General Permit. Contractor shall comply with all conditions of the most recent iteration of the National Pollutant Discharge Elimination System General Permit for Storm Water Discharges Associated with Construction Activity, issued by the California State Water Resources Control Board (“Permit”). It shall be Contractor’s sole responsibility to file a Notice of Intent and procure coverage under the Permit for all construction activity which results in the disturbance of more than one DRAFTtio
work per work p
on specified on spe
ders. This Project is s ect is F
Industrial Relations. It ndustrial Relations. It
cost of complying w st of com
able law. Any stop orde Any s
ctor or any subcontr or or any subco
elay, shall be Contracto shall be Contracto
h stop orders shall be stop orders shall be
ated damages and sh ated damages a
nify and hold the nify and hold City, it
claim or liability arising aim or liability arising
inst Contractor or any s ontractor or any s
mance of Work; Jobsite mance of Work; Jobs DR
Water Quality Ma Water Quality
1.1 n
55452.01510\32977834.2
8 acre of total land area or which is part of a larger common area of development or sale. Prior to initiating work, Contractor shall be solely responsible for preparing and implementing a Storm Water Pollution Prevention Plan (SWPPP) as required by the Permit. If required by the City, Contractor shall be responsible for procuring, implementing and complying with the provisions of the Permit and the SWPPP, including the standard provisions, and monitoring and reporting requirements as required by the Permit. The Permit requires the SWPPP to be a “living document” that changes as necessary to meet the conditions and requirements of the job site as it progresses through difference phases of construction and is subject to different weather conditions. It shall be Contractor’s sole responsibility to update the SWPPP as necessary to address conditions at the project site.
3.8.1.3 Other Water Quality Rules Regulations and Policies.
Contractor shall comply with the lawful requirements of any applicable municipality, drainage City, or local agency regarding discharges of storm water to separate storm drain systems or other watercourses under their jurisdiction, including applicable requirements in municipal storm water management programs.
3.8.1.4 Cost of Compliance. Storm, surface, nuisance, or other waters may be encountered at various times during construction of The Work. Therefore, the Contractor, by submitting a Bid, hereby acknowledges that it has investigated the risk arising from such waters, has prepared its Bid accordingly, and assumes any and all risks and liabilities arising therefrom.
3.8.1.5 Liability for Non-Compliance. Failure to comply with the Permit is a violation of federal and state law. Pursuant to the indemnification provisions of this Contract, Contractor hereby agrees to defend, indemnify and hold harmless the City and its officials, officers, employees, volunteers and agents for any alleged violations. In addition, City may seek damages from Contractor for any delay in completing the Work in accordance with the Contract, if such delay is caused by or related to Contractor’s failure to comply with the Permit.
3.8.1.6 Reservation of Right to Defend. City reserves the right to defend any enforcement action brought against the City for Contractor’s failure to comply with the Permit or any other relevant water quality law, regulation, or policy. Pursuant to the indemnification provisions of this Contract, Contractor hereby agrees to be bound by, and to reimburse the City for the costs (including the City’s attorney’s fees) associated with, any settlement reached between the City and the relevant enforcement entity.
3.8.1.7 Training. In addition to the standard of performance requirements set forth in paragraph 3.4, Contractor warrants that all employees and subcontractors shall have sufficient skill and experience to perform the Work assigned to them without impacting water quality in violation of the laws, regulations and policies described in paragraph 3.8.1. Contractor further warrants that it, its employees and subcontractors will receive adequate training, as determined by City, regarding the requirements of the laws, regulations and policies described in paragraph 3.8.1 as they may relate to the Work provided under this Agreement. Upon request, City will provide the Contractor with a list of training programs that meet the requirements of this paragraph.
3.8.2 Safety. Contractor shall execute and maintain its work so as to avoid injury or damage to any person or property. Contractor shall comply with the requirements of the specifications relating to safety measures applicable in particular operations or kinds of work. In carrying out its Work, Contractor shall at all times be in compliance with all applicable local, state DRAFTme
e. Storm, surface . Storm, s
onstruction of The W onstruction of T
s that it has investigate s that it has investiga
assumes any and all ri
lity for Non y for No -Complianc ompl
e law. Pursuant to the w. Pursuant to the
to defend, indemnify
nteers and agents nteers and agen for a
actor for any delay in co actor for any delay in
sed by or ed by or related to Co
.8.1.6 Reservati Re
ent action brought agai ent action brought ag
er relevant water q
ions of this Con ions of this Co
the costs (
n the C
55452.01510\32977834.2
9 and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of employees appropriate to the nature of the Work and the conditions under which the Work is to be performed. Safety precautions as applicable shall include, but shall not be limited to, adequate life protection and lifesaving equipment; adequate illumination for underground and night operations; instructions in accident prevention for all employees, such as machinery guards, safe walkways, scaffolds, ladders, bridges, gang planks, confined space procedures, trenching and shoring, fall protection and other safety devices, equipment and wearing apparel as are necessary or lawfully required to prevent accidents or injuries; and adequate facilities for the proper inspection and maintenance of all safety measures. Furthermore, Contractor shall prominently display the names and telephone numbers of at least two medical doctors practicing in the vicinity of the Project, as well as the telephone number of the local ambulance service, adjacent to all telephones at the Project site.
3.8.3 Laws and Regulations. Contractor shall keep itself fully informed of and in compliance with all local, state and federal laws, rules and regulations in any manner affecting the performance of the Contract or the Work, including all Cal/OSHA requirements, and shall give all notices required by law. Contractor shall be liable for all violations of such laws and regulations in connection with Work. If Contractor observes that the drawings or specifications are at variance with any law, rule or regulation, it shall promptly notify the City in writing. Any necessary changes shall be made by written change order. If Contractor performs any work knowing it to be contrary to such laws, rules and regulations and without giving written notice to the City, Contractor shall be solely responsible for all costs arising therefrom. City is a public entity of the State of California subject to certain provisions of the Health & Safety Code, Government Code, Public Contract Code, and Labor Code of the State. It is stipulated and agreed that all provisions of the law applicable to the public contracts of a municipality are a part of this Contract to the same extent as though set forth herein and will be complied with. Contractor shall defend, indemnify and hold City, its officials, officers, employees and agents free and harmless, pursuant to the indemnification provisions of this Contract, from any claim or liability arising out of any failure or alleged failure to comply with such laws, rules or regulations.
3.8.4 Permits and Licenses. Contractor shall be responsible for securing City permits and licenses necessary to perform the Work described herein, including, but not limited to, any required business license. While Contractor will not be charged a fee for any City permits, Contractor shall pay the City’s business license fee, if any. Any ineligible contractor or subcontractor pursuant to Labor Code Sections 1777.1 and 1777.7 may not perform work on this Project.
3.8.5 Trenching Work. If the Total Contract Price exceeds $25,000 and if the Work governed by this Contract entails excavation of any trench or trenches five (5) feet or more in depth, Contractor shall comply with all applicable provisions of the California Labor Code, including Section 6705. To this end, Contractor shall submit for City’s review and approval a detailed plan showing the design of shoring, bracing, sloping, or other provisions to be made for worker protection from the hazard of caving ground during the excavation of such trench or trenches. If such plan varies from the shoring system standards, the plan shall be prepared by a registered civil or structural engineer.
3.8.6 Hazardous Materials and Differing Conditions. As required by California Public Contract Code Section 7104, if this Contract involves digging trenches or other excavations that extend deeper than four (4) feet below the surface, Contractor shall promptly, and prior to disturbance of any conditions, notify City of: (1) any material discovered in excavation that Contractor believes to be a hazardous waste that is required to be removed to a Class I, Class II DRAFTlat
OSHA re OSHA
olations of su olation
rawings or specific awings or s
he City in writing. Any riting
r performs any work kno r performs any work k
iving written notice to t ving written notice to t
om. City is a public ent is a p
& Safety Code, Govern & Safety Code
s stipulated stipulated and agree nd ag
municipality are a part o ipality are a part o
e complied with. Contra complied with. Contra
ployees and agents f ployees and ag
is Contract, from any c is Contract, from an
h such laws, rules or reg such laws, rules or reg
ermits and Licenses ermits and Lice .
DR
necessary to perform necessary to perform
ness license. While C
the City’s busi
o Labor Cod o Labor Co
55452.01510\32977834.2
10 or Class III disposal site; (2) subsurface or latent physical conditions at the site differing from those indicated by City; and (3) unknown physical conditions of an unusual nature at the site, significantly different from those ordinarily encountered in such contract work. Upon notification, City shall promptly investigate the conditions to determine whether a change order is appropriate.
In the event of a dispute, Contractor shall not be excused from any scheduled completion date and shall proceed with all Work to be performed under the Contract, but shall retain all rights provided by the Contract or by law for making protests and resolving the dispute.
3.8.7 Underground Utility Facilities. To the extent required by Section 4215 of the California Government Code, City shall compensate Contractor for the costs of: (1) locating and repairing damage to underground utility facilities not caused by the failure of Contractor to exercise reasonable care; (2) removing or relocating underground utility facilities not indicated in the construction drawings; and (3) equipment necessarily idled during such work. Contractor shall not be assessed liquidated damages for delay caused by failure of City to provide for removal or relocation of such utility facilities.
3.8.8 Air Quality. Contractor must fully comply with all applicable laws, rules and regulations in furnishing or using equipment and/or providing services, including, but not limited to, emissions limits and permitting requirements imposed by the California Air Resources Board (CARB). Although CARB limits and requirements are more broad, Contractor shall specifically be aware of their application to "portable equipment", which definition is considered by CARB to include any item of equipment with a fuel-powered engine. Contractor shall indemnify City against any fines or penalties imposed by CARB, or any other governmental or regulatory agency for violations of applicable laws, rules and/or regulations by Contractor, its subcontractors, or others for whom Contractor is responsible under its indemnity obligations provided for in this Agreement.
3.8.9 State Recycling Mandates. Contractor shall comply with State Recycling Mandates. Any recyclable materials/debris collected by the contractor that can be feasibly diverted via reuse or recycling must be hauled by the appropriate handler for reuse or recycling.
3.9 Completion of Work. When Contractor determines that it has completed the Work required herein, Contractor shall so notify City in writing and shall furnish all labor and material releases required by this Contract. City shall thereupon inspect the Work. If the Work is not acceptable to the City, the City shall indicate to Contractor in writing the specific portions or items of Work which are unsatisfactory or incomplete. Once Contractor determines that it has completed the incomplete or unsatisfactory Work, Contractor may request a reinspection by the City. Once the Work is acceptable to City, City shall pay to Contractor the Total Contract Price remaining to be paid, less any amount which City may be authorized or directed by law to retain.
Payment of retention proceeds due to Contractor shall be made in accordance with Section 7107 of the California Public Contract Code.
3.10 Claims; Government Code Claim Compliance.
3.10.1 Intent. Effective January 1, 1991, Section 20104 et seq., of the California Public Contract Code prescribes a process utilizing informal conferences, non-binding judicial supervised mediation, and judicial arbitration to resolve disputes on construction claims of $375,000 or less. Effective January 1, 2017, Section 9204 of the Public Contract Code prescribes a process for negotiation and mediation to resolve disputes on construction claims. The intent of this Section is to implement Sections 20104 et seq. and Section 9204 of the California Public Contract Code. This Section shall be construed to be consistent with said statutes.
DRAFTply with all ply wit ap
ding services, inc ding service
ed by the California A ed by the Califo
re more broad, Contra re more broad, Cont
ent", which definition is nt", which definition is
ed engine. Contractor s Co
or any other governme or any other go
regulations egulations by Contrac Cont
er its indemnity obligatio indemnity obligatio
cling Mandates. Cont RA
aterials/debris collected aterials/debris colle
g must be hauled by th must be hauled by th
on of Work on of Wor . When Con Wh DR
tractor shall so notify tractor shall so notify C
y this Contract. y this Contract. City
the City shall ind all
satisfactory
or unsa
pt
55452.01510\32977834.2
11 3.10.2 Claims. For purposes of this Section, “Claim” means a separate demand by the Contractor, after a change order duly requested in accordance with the terms of this Contract has been denied by the City, for (A) a time extension, (B) payment of money or damages arising from Work done by or on behalf of the Contractor pursuant to the Contract, or (C) an amount the payment of which is disputed by the City. A “Claim” does not include any demand for payment for which the Contractor has failed to provide notice, request a change order, or otherwise failed to follow any procedures contained in the Contract Documents. Claims governed by this Section may not be filed unless and until the Contractor completes all procedures for giving notice of delay or change and for the requesting of a time extension or change order, including but not necessarily limited to the change order procedures contained herein, and Contractor’s request for a change has been denied in whole or in part. Claims governed by this Section must be filed no later than fourteen (14) days after a request for change has been denied in whole or in part or after any other event giving rise to the Claim. The Claim shall be submitted in writing to the City and shall include on its first page the following in 16 point capital font: “THIS IS A CLAIM.” Furthermore, the claim shall include the documents necessary to substantiate the claim. Nothing in this Section is intended to extend the time limit or supersede notice requirements otherwise provided by contract for the filing of claims, including all requirements pertaining to compensation or payment for extra Work, disputed Work, and/or changed conditions. Failure to follow such contractual requirements shall bar any claims or subsequent lawsuits for compensation or payment thereon.
3.10.3 Supporting Documentation. The Contractor shall submit all claims in the following format:
3.10.3.1 Summary of claim merit and price, reference Contract Document provisions pursuant to which the claim is made
3.10.3.2 List of documents relating to claim:
(A) Specifications
(B) Drawings
(C) Clarifications (Requests for Information)
(D) Schedules
(E) Other
3.10.3.3 Chronology of events and correspondence
3.10.3.4 Analysis of claim merit
3.10.3.5 Analysis of claim cost
3.10.3.6 Time impact analysis in CPM format
3.10.3.7 If Contractor’s claim is based in whole or in part on an allegation of errors or omissions in the Drawings or Specifications for the Project, Contractor shall provide a summary of the percentage of the claim subject to design errors or omissions and shall obtain a certificate of merit in support of the claim of design errors and omissions.
DRAFTsu
de notic de n
irements per ireme
ged conditions. F ged conditi
ubsequent lawsuits fo ubsequent lawsu
on. The Contractor sh The Con A
ummary of claim mer ary of claim mer
ich the claim is made ch the claim is made
List of documents t of docume
(A) Spec
(B)
(C
55452.01510\32977834.2
12 3.10.3.8 Cover letter and certification of validity of the claim, including any claims from subcontractors of any tier, in accordance with Government Code section 12650 et seq.
3.10.4 City’s Response. Upon receipt of a claim pursuant to this Section, City shall conduct a reasonable review of the claim and, within a period not to exceed 45 days, shall provide the Contractor a written statement identifying what portion of the claim is disputed and what portion is undisputed. Any payment due on an undisputed portion of the claim will be processed and made within 60 days after the public entity issues its written statement.
3.10.4.1 If City needs approval from its governing body to provide the Contractor a written statement identifying the disputed portion and the undisputed portion of the claim, and the governing body does not meet within the 45 days or within the mutually agreed to extension of time following receipt of a claim sent by registered mail or certified mail, return receipt requested, City shall have up to three days following the next duly publicly noticed meeting of the governing body after the 45-day period, or extension, expires to provide the Contractor a written statement identifying the disputed portion and the undisputed portion.
3.10.4.2 Within 30 days of receipt of a claim, City may request in writing additional documentation supporting the claim or relating to defenses or claims City may have against the Contractor. If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement of City and the Contractor.
3.10.4.3 City’s written response to the claim, as further documented, shall be submitted to the Contractor within 30 days (if the claim is less than $50,000, within 15 days) after receipt of the further documentation, or within a period of time no greater than that taken by the Contractor in producing the additional information or requested documentation, whichever is greater.
3.10.5 Meet and Confer. If the Contractor disputes City’s written response, or City fails to respond within the time prescribed, the Contractor may so notify City, in writing, either within 15 days of receipt of City’s response or within 15 days of City’s failure to respond within the time prescribed, respectively, and demand an informal conference to meet and confer for settlement of the issues in dispute. Upon receipt of a demand, City shall schedule a meet and confer conference within 30 days for settlement of the dispute.
3.10.6 Mediation. Within 10 business days following the conclusion of the meet and confer conference, if the claim or any portion of the claim remains in dispute, City shall provide the Contractor a written statement identifying the portion of the claim that remains in dispute and the portion that is undisputed. Any payment due on an undisputed portion of the claim shall be processed and made within 60 days after City issues its written statement. Any disputed portion of the claim, as identified by the Contractor in writing, shall be submitted to nonbinding mediation, with City and the Contractor sharing the associated costs equally. City and Contractor shall mutually agree to a mediator within 10 business days after the disputed portion of the claim has been identified in writing, unless the parties agree to select a mediator at a later time.
3.10.6.1 If the Parties cannot agree upon a mediator, each Party shall select a mediator and those mediators shall select a qualified neutral third party to mediate with regard to the disputed portion of the claim. Each Party shall bear the fees and costs charged by its respective mediator in connection with the selection of the neutral mediator.
DRAFTy p
o provi o pro
d portion. d port
f receipt of a claim, f receipt of a cl C
m or relating to defense m or relating to defen
ion is thereafter require on is thereafter require
mutual agreement of tual agree C
s written response to th written response t
thin 30 days (if the cla 30 days (if the cla
umentation, or within a
cing the additional inf cing the addition
t and Confer. If the Con Confer. If the Con DR
he time prescribed, the he time prescrib
eipt of eipt of City’s response o ’s response
spectively, and dema
es in dispute. Up es in dispute.
30 days for 30 days fo
on
55452.01510\32977834.2
13 3.10.6.2 For purposes of this section, mediation includes any nonbinding process, including, but not limited to, neutral evaluation or a dispute review board, in which an independent third party or board assists the Parties in dispute resolution through negotiation or by issuance of an evaluation. Any mediation utilized shall conform to the timeframes in this section.
3.10.6.3 Unless otherwise agreed to by City and the Contractor in writing, the mediation conducted pursuant to this section shall excuse any further obligation under Section 20104.4 to mediate after litigation has been commenced.
3.10.6.4 The mediation shall be held no earlier than the date the Contractor completes the Work or the date that the Contractor last performs Work, whichever is earlier. All unresolved claims shall be considered jointly in a single mediation, unless a new unrelated claim arises after mediation is completed.
3.10.7 Procedures After Mediation. If following the mediation, the claim or any portion remains in dispute, the Contractor must file a claim pursuant to Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code. For purposes of those provisions, the running of the period of time within which a claim must be filed shall be tolled from the time the Contractor submits his or her written claim pursuant to subdivision (a) until the time the claim is denied, including any period of time utilized by the meet and confer conference or mediation.
3.10.8 Civil Actions. The following procedures are established for all civil actions filed to resolve claims subject to this Section:
3.10.8.1 Within 60 days, but no earlier than 30 days, following the filing or responsive pleadings, the court shall submit the matter to non-binding mediation unless waived by mutual stipulation of both parties or unless mediation was held prior to commencement of the action in accordance with Public Contract Code section 9204 and the terms of these procedures.. The mediation process shall provide for the selection within 15 days by both parties of a disinterested third person as mediator, shall be commenced within 30 days of the submittal, and shall be concluded within 15 days from the commencement of the mediation unless a time requirement is extended upon a good cause showing to the court.
3.10.8.2 If the matter remains in dispute, the case shall be submitted to judicial arbitration pursuant to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, notwithstanding Section 1114.11 of that code. The Civil Discovery Act of 1986 (Article 3 (commencing with Section 2016) of Chapter 3 of Title 3 of Part 4 of the Code of Civil Procedure) shall apply to any proceeding brought under this subdivision consistent with the rules pertaining to judicial arbitration.
3.10.8.3 In addition to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, (A) arbitrators shall, when possible, be experienced in construction law, and (B) any party appealing an arbitration award who does not obtain a more favorable judgment shall, in addition to payment of costs and fees under that chapter, also pay the attorney’s fees on appeal of the other party.
3.10.9 Government Code Claims. In addition to any and all contract requirements pertaining to notices of and requests for compensation or payment for extra work, disputed work, claims and/or changed conditions, Contractor must comply with the claim procedures set forth in Government Code sections 900 et seq. prior to filing any lawsuit against the City. Such DRAFTg the m g the
pursuant to pursu
on 910) of Part 3 on 910) of
ovisions, the running o ovisions, the run
m the time the Contract m the time the Contra
me the claim is denied
e or mediation. mediation
ollowing procedures are lowing procedures
ction:
Within 60 days, but ithin 60 day
he court shall submit th he court shall subm
of both parties or unless f both parties or unles
ce with Public Contrac th Public Contrac
ation process shall prov ation process sh
d person as mediator, s d person as mediator
ded within 15 days fro
ed upon a good c ed upon a goo
8.2 to
55452.01510\32977834.2
14 Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to extra work, disputed work, claims, and/or changed conditions have been followed by Contractor. If no such Government Code claim is submitted, or if any prerequisite contractual requirements are not otherwise satisfied as specified herein, Contractor shall be barred from bringing and maintaining a valid lawsuit against the City. A Government Code claim must be filed no earlier than the date the work is completed or the date the Contractor last performs work on the Project, whichever occurs first. A Government Code claim shall be inclusive of all unresolved claims unless a new unrelated claim arises after the Government Code claim is submitted.
3.10.10 Non-Waiver. City’s failure to respond to a claim from the Contractor within the time periods described in this Section or to otherwise meet the time requirements of this Section shall result in the claim being deemed rejected in its entirety. City’s failure to respond shall not waive City’s rights to any subsequent procedures for the resolution of disputed claims.
3.11 Loss and Damage. Except as may otherwise be limited by law, Contractor shall be responsible for all loss and damage which may arise out of the nature of the Work agreed to herein, or from the action of the elements, or from any unforeseen difficulties which may arise or be encountered in the prosecution of the Work until the same is fully completed and accepted by City. In the event of damage proximately caused by an Act of God, as defined by Section 7105 of the Public Contract Code, the City may terminate this Contract pursuant to Section 3.17.3; provided, however, that the City needs to provide Contractor with only one (1) day advanced written notice.
3.12 Indemnification.
3.12.1 Scope of Indemnity. To the fullest extent permitted by law, Contractor shall defend (with counsel reasonably approved by City), indemnify and hold the City, its officials, employees, agents and authorized volunteers free and harmless from any and all claims, demands, causes of action, suits, actions, proceedings, costs, expenses, liability, judgments, awards, decrees, settlements, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, (collectively, “Claims”) in any manner arising out of, pertaining to, or incident to any alleged acts, errors or omissions, or willful misconduct of Contractor, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Contractor’s services, the Project or this Agreement, including without limitation the payment of all consequential damages, expert witness fees and attorneys’ fees and other related costs and expenses. Notwithstanding the foregoing, to the extent required by Civil Code section 2782, Contractor’s indemnity obligation shall not apply to liability for damages for death or bodily injury to persons, injury to property, or any other loss, damage or expense arising from the sole or active negligence or willful misconduct of the City or the City’s agents, servants, or independent contractors who are directly responsible to the City, or for defects in design furnished by those persons.
3.12.2 Additional Indemnity Obligations. In addition, Contractor shall pay and satisfy any judgment, award or decree that may be rendered against City or its officials, employees, agents and authorized volunteers as part of any such claim, suit, action or other proceeding. Contractor shall also reimburse City for the cost of any settlement paid by City or its officials, employees, agents and authorized volunteers as part of any such claim, suit, action or other proceeding. Such reimbursement shall include payment for City's attorney's fees and costs, including expert witness fees. Contractor shall reimburse City and its officials, employees, agents and authorized volunteers, for any and all legal expenses and costs incurred by each of them in DRAFTbe limite be lim
of the natur of the
foreseen difficultie oreseen d
same is fully complet same is fully co
y an Act of God, as def y an Act of God, as d
nate this Contract purs
vide Contractor with o Contract
pe of Indemnity. To RA
unsel reasonably appro unsel reasonably a
nts and authorized volu and authorized vol
s of action, suits, act action, suits, act
crees, settlements, loss settlement
including wrongful dea including wrongful de
incident to any alleg
s, officers, employ s, officers, emp
he Contract
conse
s
55452.01510\32977834.2
15 connection therewith or in enforcing the indemnity herein provided. Contractor's obligation to indemnify shall not be restricted to insurance proceeds, if any, received by the City, its officials, employees, agents and authorized volunteers.
3.13 Insurance. Contractor agrees to procure and maintain, at Contractor’s expense all insurance specified in Exhibit “H” attached hereto and by this reference incorporated herein.
Contractor shall require all subcontractors to carry the same policies and limits of insurance that the Contractor is required to maintain, unless otherwise approved in writing by the City.
3.13.1 3.14 Bond Requirements.
3.14.1 Payment Bond. If required by law or otherwise specifically requested by City in Exhibit “C” attached hereto and incorporated herein by reference, Contractor shall execute and provide to City concurrently with this Contract a Payment Bond in an amount required by the City and in a form provided or approved by the City. If such bond is required, no payment will be made to Contractor until the bond has been received and approved by the City.
3.14.2 Performance Bond. If specifically requested by City in Exhibit “C” attached hereto and incorporated herein by reference, Contractor shall execute and provide to City concurrently with this Contract a Performance Bond in an amount required by the City and in a form provided or approved by the City. If such bond is required, no payment will be made to Contractor until the bond has been received and approved by the City.
3.14.3 Bond Provisions. Should, in City’s sole opinion, any bond become insufficient or any surety be found to be unsatisfactory, Contractor shall renew or replace the effected bond within (ten) 10 days of receiving notice from City. In the event the surety or Contractor intends to reduce or cancel any required bond, at least thirty (30) days prior written notice shall be given to the City, and Contractor shall post acceptable replacement bonds at least ten (10) days prior to expiration of the original bonds. No further payments shall be deemed due or will be made under this Contract until any replacement bonds required by this Section are accepted by the City. To the extent, if any, that the Total Contract Price is increased in accordance with the Contract, Contractor shall, upon request of the City, cause the amount of the bond to be increased accordingly and shall promptly deliver satisfactory evidence of such increase to the City. If Contractor fails to furnish any required bond, the City may terminate the Contract for cause.
3.14.4 Surety Qualifications. Only bonds executed by an admitted surety insurer, as defined in California Code of Civil Procedure Section 995.120, shall be accepted. If a California-admitted surety insurer issuing bonds does not meet these requirements, the insurer will be considered qualified if it is in conformance with Section 995.660 of the California Code of Civil Procedure, and proof of such is provided to the City.
3.15 Warranty. Contractor warrants all Work under the Contract (which for purposes of this Section shall be deemed to include unauthorized work which has not been removed and any non-conforming materials incorporated into the Work) to be of good quality and free from any defective or faulty material and workmanship. Contractor agrees that for a period of one year (or the period of time specified elsewhere in the Contract or in any guarantee or warranty provided by any manufacturer or supplier of equipment or materials incorporated into the Work, whichever is later) after the date of final acceptance, Contractor shall within ten (10) days after being notified DRAFTeren
Bond in a Bond
bond is requi bond i
d approved by the d approved b C
cally requested by City
Contractor shall execu
Bond in an amount re d in an a
such bond is required, such bond is re
ed and approved by th d and approved by
ons. Should, in ns. Should, in City R
nd to be unsatisfactory nd to be unsatisf
days of receiving noti days of receiving n
e or cancel any require or cancel any require
e City, and Contractor s and Contractor s
xpiration of the original xpiration of the or
er this Contract until a er this Contract until
. To the extent, if any . To the extent, if
tractor shall, upo tractor shall, u
d shall pro d shall pr
furnis
55452.01510\32977834.2
16 in writing by the City of any defect in the Work or non-conformance of the Work to the Contract, commence and prosecute with due diligence all Work necessary to fulfill the terms of the warranty at its sole cost and expense. Contractor shall act sooner as requested by the City in response to an emergency. In addition, Contractor shall, at its sole cost and expense, repair and replace any portions of the Work (or work of other contractors) damaged by its defective Work or which becomes damaged in the course of repairing or replacing defective Work. For any Work so corrected, Contractor’s obligation hereunder to correct defective Work shall be reinstated for an additional one year period, commencing with the date of acceptance of such corrected Work.
Contractor shall perform such tests as the City may require to verify that any corrective actions, including, without limitation, redesign, repairs, and replacements comply with the requirements of the Contract. All costs associated with such corrective actions and testing, including the removal, replacement, and reinstitution of equipment and materials necessary to gain access, shall be the sole responsibility of Contractor. All warranties and guarantees of subcontractors, suppliers and manufacturers with respect to any portion of the Work, whether express or implied, are deemed to be obtained by Contractor for the benefit of the City, regardless of whether or not such warranties and guarantees have been transferred or assigned to the City by separate agreement and Contractor agrees to enforce such warranties and guarantees, if necessary, on behalf of the City. In the event that Contractor fails to perform its obligations under this Section, or under any other warranty or guaranty under this Contract, to the reasonable satisfaction of the City, the City shall have the right to correct and replace any defective or non-conforming Work and any work damaged by such work or the replacement or correction thereof at Contractor’s sole expense.
Contractor shall be obligated to fully reimburse the City for any expenses incurred hereunder upon demand.
3.16 Employee/Labor Certifications.
3.16.1 Contractor’s Labor Certification. By its signature hereunder, Contractor certifies that he is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker’s Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Work. A certification form for this purpose, which is attached to this Contract as Exhibit “D” and incorporated herein by reference, shall be executed simultaneously with this Contract.
3.16.2 Equal Opportunity Employment. Contractor represents that it is an equal opportunity employer and that it shall not discriminate against any employee or applicant for employment because of race, religion, color, national origin, ancestry, sex, age or other interests protected by the State or Federal Constitutions. Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination.
3.16.3 Verification of Employment Eligibility. By executing this Contract, Contractor verifies that it fully complies with all requirements and restrictions of state and federal law respecting the employment of undocumented aliens, including, but not limited to, the Immigration Reform and Control Act of 1986, as may be amended from time to time, and shall require all subcontractors and sub-subcontractors to comply with the same.
3.17 General Provisions.
3.17.1 City’s Representative. The City hereby designates the General Manager, or his or her designee, to act as its representative for the performance of this Contract (“City’s DRAFTrdl
to theC
antees, if nec antees
ations under this S ations unde
easonable satisfaction isf
ctive or non ctive -conformin
orrection thereof at Co rrection thereof at Co
the City for any expense for any
ations.
RA
s Labor Certification. s Labor Certifica
e provisions of Section e provisions of Sect
insured against liability nsured against liability
nce with the provisions th the provisions
mencing the performanc mencing the perfor
this Contract as Exhib this Contract as Exhi
ously with this Contra
ual Opport
that it D
55452.01510\32977834.2
17 Representative”). City’s Representative shall have the power to act on behalf of the City for all purposes under this Contract. Contractor shall not accept direction or orders from any person other than the City’s Representative or his or her designee.
3.17.2 Contractor’s Representative. Before starting the Work, Contractor shall submit in writing the name, qualifications and experience of its proposed representative who shall be subject to the review and approval of the City
³ƍ&RQWUDFWRU¶V 5HSUHVHQWDWLYH´
)ROORZLQJ
approval by the City, Contractor’s Representative shall have full authority to represent and act on behalf of Contractor for all purposes under this Contract. Contractor’s Representative shall supervise and direct the Work, using his best skill and attention, and shall be responsible for all construction means, methods, techniques, sequences and procedures and for the satisfactory coordination of all portions of the Work under this Contract. Contractor’s Representative shall devote full time to the Project and either he or his designee, who shall be acceptable to the City, shall be present at the Work site at all times that any Work is in progress and at any time that any employee or subcontractor of Contractor is present at the Work site. Arrangements for responsible supervision, acceptable to the City, shall be made for emergency Work which may be required. Should Contractor desire to change its Contractor’s Representative, Contractor shall provide the information specified above and obtain the City’s written approval.
3.17.3 Termination. This Contract may be terminated by City at any time, either with our without cause, by giving Contractor three (3) days advance written notice. In the event of termination by City for any reason other than the fault of Contractor, City shall pay Contractor for all Work performed up to that time as provided herein. In the event of breach of the Contract by Contractor, City may terminate the Contract immediately without notice, may reduce payment to Contractor in the amount necessary to offset City’s resulting damages, and may pursue any other available recourse against Contractor. Contractor may not terminate this Contract except for cause. In the event this Contract is terminated in whole or in part as provided, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated. Further, if this Contract is terminated as provided, City may require Contractor to provide all finished or unfinished documents, data, diagrams, drawings, materials or other matter prepared or built by Contractor in connection with its performance of this Contract.
3.17.4 Contract Interpretation. Should any question arise regarding the meaning or import of any of the provisions of this Contract or written or oral instructions from City, the matter shall be referred to City’s Representative, whose decision shall be binding upon Contractor.
3.17.5 Anti-Trust Claims. This provision shall be operative if this Contract is applicable to California Public Contract Code Section 7103.5. In entering into this Contract to supply goods, services or materials, Contractor hereby offers and agrees to assign to the City all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Section 15) or under the Cartwright Act (Chapter 2, commencing with Section 16700, of Part 2 of Division 7 of the Business and Professions Code) arising from purchases of goods, services, or materials pursuant to the Contract. This assignment shall be made and become effective at the time the City tender final payment to Contractor, without further acknowledgment by the Parties.
3.17.6 Notices. All notices hereunder and communications regarding interpretation of the terms of the Contract or changes thereto shall be provided by the mailing thereof by registered or certified mail, return receipt requested, postage prepaid and addressed as follows:
DRAFTWo
e for em e for
or’s Represe or’s R
ty’s written approv ’s written
ay be terminated by C
(3) days advance writ
n the fault of Contractor e fault of C
vided herein. In the ev vided herein.
ntract immediately witho ract immediately w
to offsetCity’s resultin
ntractor. Contractor ma tractor. Contractor ma
tract is terminated in w tract is terminate
n such manner as it m n such manner as i
er, if this Contract is r, if this Contract is
nished or unfinished d d or unfinished d
d or built by Contractor d or built by Cont
.4 Contract Co Interpreta D
e provisions of t e provisions o
d to City’s
55452.01510\32977834.2
18 CONTRACTOR:
O’Connell Engineering & Construction, Inc.
36572 Deauville Rd.
Winchester, CA 92596
Attn: Rhonda O’Connell, President
CITY:
City of San Clemente
910 Calle Negocio
San Clemente, CA 92673
Attn: Amir Ilkhanipour, Principal Civil Engineer
Any notice so given shall be considered received by the other Party three (3) days after deposit in the U.S. Mail as stated above and addressed to the Party at the above address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.
3.17.7 Time of Essence. Time is of the essence in the performance of this Contract.
3.17.8 Assignment Forbidden. Contractor shall not, either voluntarily or by action of law, assign or transfer this Contract or any obligation, right, title or interest assumed by Contractor herein without the prior written consent of City. If Contractor attempts an assignment or transfer of this Contract or any obligation, right, title or interest herein, City may, at its option, terminate and revoke the Contract and shall thereupon be relieved from any and all obligations to Contractor or its assignee or transferee.
3.17.9 No Third Party Beneficiaries. There are no intended third party beneficiaries of any right or obligation assumed by the Parties.
3.17.10 Laws, Venue, and Attorneys’ Fees. This Agreement shall be interpreted in accordance with the laws of the State of California. If any action is brought to interpret or enforce any term of this Agreement, the action shall be brought in a state or federal court situated in the County of Orange, State of California.
3.17.11 Counterparts. This Contract may be executed in counterparts, each of which shall constitute an original.
3.17.12 Successors. The Parties do for themselves, their heirs, executors, administrators, successors, and assigns agree to the full performance of all of the provisions contained in this Contract.
3.17.13 [Reserved]
3.17.14 Solicitation. Contractor maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Contractor, to solicit or secure this Contract. Further, Contractor warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Contractor, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Contract. For breach or violation of this warranty, City shall have the right to terminate this Contract without liability.
DRAFTe a
urred, r urred
the essence in the p the essence in
Contractor shall not, eit tractor sha
any obligation, right, any obligation
consent of onsent o City. If Con . If
ation, right, title or inter right, title or inter
nd shall thereupon be re d shall thereupon be re
feree.
No Third Party Benef Third Party Bene R
r obligation assumed b gation assumed b
0 Laws, Venue, , Venu DR
dance with the laws
ny term of this Ag ny term of this
nty ofOrang
C
55452.01510\32977834.2
19 3.17.15 Conflict of Interest. Contractor maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Contractor, to solicit or secure this Agreement. Further, Contractor warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Contractor, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability. For the term of this Contract, no official, officer or employee of City, during the term of his or her service with City, shall have any direct interest in this Contract, or obtain any present or anticipated material benefit arising therefrom. In addition, Contractor agrees to file, or to cause its employees or subcontractors to file, a Statement of Economic Interest with the City’s Filing Officer as required under state law in the performance of the Work.
3.17.16 Certification of License.
3.17.16.1 Contractor certifies that as of the date of execution of this Contract, Contractor has a current contractor’s license of the classification indicated below under Contractor’s signature.
3.17.16.2 Contractors are required by law to be licensed and regulated by the Contractors’ State License Board which has jurisdiction to investigate complaints against contractors if a complaint regarding a patent act or omission is filed within four (4) years of the date of the alleged violation. A complaint regarding a latent act or omission pertaining to structural defects must be filed within ten (10) years of the date of the alleged violation. Any questions concerning a contractor may be referred to the Registrar, Contractors’ State License Board, P.O.
Box 26000, Sacramento, California 95826.
3.17.17 Authority to Enter Contract. Each Party warrants that the individuals who have signed this Contract have the legal power, right and authority to make this Contract and bind each respective Party.
3.17.18 Entire Contract; Modification. This Contract contains the entire agreement of the Parties with respect to the subject matter hereof, and supersedes all prior negotiations, understandings or agreements. This Contract may only be modified by a writing signed by both Parties.
3.17.19 Non-Waiver. None of the provisions of this Agreement shall be considered waived by either party, unless such waiver is specifically specified in writing.
3.17.20 City’s Right to Employ Other Contractors. City reserves right to employ other contractors in connection with this Project or other projects.
DRAFTs of th s of
classificatio class
required by law to be lic required by law to be
as jurisdiction to investi s jurisdiction to investi
ct or omission is filed w r omission
arding a latent act or om arding a latent
rs of the date of the al of the date of the
d to the Registrar, Cont he Registrar, Cont
5826.
uthority uthor to Enter Con RA
this Contract have the his Contract have the
spective Party. ve Party.
8 Entire Contrac ire Contr DR
Parties with respect to
andings or agreem andings or agre
N
55452.01510\32977834.2
20 [SIGNATURES ON NEXT PAGE]
55452.01510\32977834.2
21 IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be duly executed on the respective dates set forth opposite of their signatures.
CITY OF SAN CLEMENTE
By:________________________________
ATTEST: Its:_______________________________
______________________________ Dated: ____________________, 20____ CITY CLERK of the City of
San Clemente, California
APPROVED AS TO FORM:
BEST BEST & KRIEGER
____________________________
City Attorney
APPROVED AS TO AVAILABILITY
OF FUNDING:
________________________________
Finance Authorization
__________________________
(“CONTRACTOR”)
By:_____________________________
Its:_____________________________
Dated: __________________, 20____
DRAFT ILITY
____________ ____________
55452.01510\32977834.2
- 22 -
EXHIBIT “A”
SERVICES / SCHEDULE
&216758&7,215(3$,5'85$7,21,67(1
:25.,1*'$<6
DRAFT
55452.01510\32977834.2
- 23 -
EXHIBIT “B”
PLANS AND SPECIFICATIONS
DRAFT
From: Cuhadaroglu, Belgin
To: [email protected]; Stelian Onufrei ([email protected]); Ramiro Acevedo Cc: Amir Ilkhanipour ([email protected]); Ohana, Jacob Subject: RE: RICHARD T. STEED PARK SLOPE EROSION REPAIRS Date: Thursday, January 26, 2023 3:33:00 PM
Attachments: Bid Form_RICHARD T. STEED PARK SLOPE EROSION REPAIRS_Revised.pdf Hi all,
Attached please see the revised bid form.
There is a change in bid item#4. The change is marked in red.
Please confirm that you received this e-mail.
Thank you.
Bel
Belgin Cuhadaroglu, P.E. | City of San Clemente
Assoc. Civil Engineer | 910 Calle Negocio, CA 92673
office: 949.361.6128 | cell: 949.426 3138 | facsimile: 949.361.8316 e-mail: [email protected]
From: Cuhadaroglu, Belgin
Sent: Thursday, January 26, 2023 2:35 PM
To: [email protected]; Stelian Onufrei ([email protected]) <[email protected]>; Ramiro Acevedo <[email protected]>
Cc: Amir Ilkhanipour ([email protected]) <[email protected]>; Ohana, Jacob <[email protected]>
Subject: RICHARD T. STEED PARK SLOPE EROSION REPAIRS
Good afternoon all,
The City of San Clemente (City) is accepting quotations to select a qualified construction firm to provide construction services for slope erosion repairs. The project site is located at Richard T. Steed Memorial Park, 247 Avenida La Pata, San Clemente, CA 92672, in City of San Clemente. (Attachment 1)
All questions regarding this Request for Quotations (RFQ) shall be directed to Belgin Cuhadaroglu, Assoc. Civil Engineer, at cuhadaroglub@san clemente.org.
Quotations, in the form of the Unit Price Quotation Form (bid form), shall be submitted by prospective Contractor that have a capable and demonstrable background in the type of work described in this RFQ. In addition, all interested firms shall have sufficient, readily available resources in the form of trained personnel, support services, safety protocols, specialized field equipment, and financial resources to carry out the work without delay or shortcomings.
Services required by this request shall be performed by a contractor who has a Class A Contractor's license in the State of California. Note that this project is subject to the prevailing wage requirements.
Each bid proposal must be accompanied by security in the form of cash, certified check, cashier's check, or bid bond in the amount of ten percent (10%) of the total bid amount. For electronic submittal of bids, the hard copy of the bid security must be received at the City of DRAFT (stely907@yahoo
[email protected]>
[email protected]
org>
SLOPE EROSION R
ente (City) is
services
Par
San Clemente Public Works office, 910 Calle Negocio, Suite 100, San Clemente, CA 92673 within 24 hours of the bid opening date and time.
The following scope provides a summary of the tasks to be completed:
Hillside (slope) due to soil erosion caused by the higher intensity of rainstorms is in need of repairs. The work to be performed, consists, in general, clear and grubbing, repair of concrete, placement of CMB and top soil etc. to necessary to complete the work. Attached please find the bid form, project location map and available record drawings (for information only purposes).
If interested, please provide quotations (a bid schedule) including, but not limited to, company’s past experiences and success.
The quotations (bid form) shall be submitted via email by 4:00 p.m. on January 30, 2023.
Attachments:
1. Project Location Map
2. Bid Form
3. Available Record Drawings (for information only).
4. Standard construction contract- City of San Clemente Thank you
Bel
Belgin Cuhadaroglu, P.E. | City of San Clemente
Assoc. Civil Engineer | 910 Calle Negocio, CA 92673
office: 949.361.6128 | cell: 949.426 3138 | facsimile: 949.361.8316 e-mail: [email protected]).
emen
ity of San Cleme
le Negocio, CA 92673
| facsimile: 949.361.83
mente.orgDR
55452.01510\32977834.2
- 24 -
EXHIBIT “C”
SPECIAL CONDITIONS
ARTICLE 1. BONDS
Within ten (10) calendar days from the date the Contractor is notified of award of the Contract, the Contractor shall deliver to the City four identical counterparts of the Performance Bond and Payment Bond on the forms supplied by the City and included as Exhibit “F” to the Contract.
Failure to do so may, in the sole discretion of City, result in the forfeiture of Contractor’s bid security. The surety supplying the bond must be an admitted surety insurer, as defined in Code of Civil Procedure Section 995.120, authorized to do business as such in the State of California and satisfactory to the City. The Performance Bond and the Payment Bond shall be for one hundred percent (100%) of the Total Contract Price.
DRAFT
55452.01510\32977834.2
- 25 -
EXHIBIT “D”
WORKERS COMPENSATION INSURANCE CERTIFICATION
WORKERS' COMPENSATION DECLARATION
I hereby affirm under penalty of perjury one of the following declarations:
(ONE OF THE BOXES BELOW MUST BE CHECKED)
I have and will maintain a certificate of consent from the California Labor Commission to self-insure for workers' compensation, as provided for by Section 3700 of the Labor Code, for the performance of the work to be performed under this contract.
I have and will maintain workers' compensation insurance, as required by Section 3700 of the Labor Code, for the performance of the work to be performed under this contract. My workers' compensation insurance carrier and policy number are:
Carrier____________________________________________________ Policy Number______________________________________________ I certify that, in the performance of the work under this Agreement, I shall not employ any person in any manner so as to become subject to the workers' compensation laws of California, and I hereby agree to indemnify, defend, and hold harmless the City of San Clemente and all of its officials, employees, and agents from and against any and all claims, liabilities, and losses relating to personal injury or death, economic losses, and property damage arising out of my failure to provide such worker’s compensation insurance. I further agree that, if I should become subject to the workers' compensation provisions of Section 3700 of the Labor Code, I shall forthwith comply with those provisions.
WARNING: FAILURE TO SECURE WORKERS’ COMPENSATION COVERAGE IS
UNLAWFUL, AND SHALL SUBJECT AN EMPLOYER TO CRIMINAL PENALTIES AND CIVIL FINES UP TO ONE HUNDRED THOUSAND DOLLARS ($100,000), IN
ADDITION TO THE COST OF COMPENSATION, DAMAGES AS PROVIDED FOR IN SECTION 3706 OF THE LABOR CODE, INTEREST, AND ATTORNEY’S FEES.
DRAFTsurance, as re surance
work to be performe work to be pe
ce carrier and policy nu ce carrier and poli
___________________ __________
___________________ ______________
mance of mance f the work unde he work unde
ner so as to become subj ner so as to become
eby agree to indemnify, by agree to indemnify
of its official s officials, employe
es, and losses relating t es, and losses re
mage arising out of my mage arising out of m
I further I fu agree that, i
f Section 3700 of f Section 3700
55452.01510\32977834.2
- 26 -
Dated: ________________________, 20____
________________________________
Consultant
By: ________________________________
________________________________
Title
________________________________
Address
________________________________ DRAFT __
55452.01510\32977834.2
- 27 -
EXHIBIT “E”
PUBLIC WORKS CONTRACTOR REGISTRATION CERTIFICATION
Pursuant to Labor Code sections 1725.5 and 1771.1, all contractors and subcontractors that wish to bid on, be listed in a bid proposal, or enter into a contract to perform public work must be registered with the Department of Industrial Relations. See http://www.dir.ca.gov/PublicWorks/PublicWorks.html for additional information.
No bid will be accepted nor any contract entered into without proof of the contractor’s and subcontractors’ current registration with the Department of Industrial Relations to perform public work.
Contractor hereby certifies that it is aware of the registration requirements set forth in Labor Code sections 1725.5 and 1771.1 and is currently registered as a contractor with the Department of Industrial Relations.1
Name of Contractor:
DIR Registration Number:
DIR Registration Expiration:_________________________
Small Project Exemption: _____ Yes or _____ No
Unless Contractor is exempt pursuant to the small project exemption, Contractor further acknowledges:
x Contractor shall maintain a current DIR registration for the duration of the project. x Contractor shall include the requirements of Labor Code sections 1725.5 and 1771.1 in its contract with subcontractors and ensure that all subcontractors are registered at the time of bid opening and maintain registration status for the duration of the project. x Failure to submit this form or comply with any of the above requirements may result in a finding that the bid is non-responsive.
Name of Contractor
Signature
Name and Title
Dated
1 If the Project is exempt from the contractor registration requirements pursuant to the small project exemption under Labor Code Sections 1725.5 and 1771.1, please mark “Yes” in response to “Small Project Exemption.”
quireme quirem
a contractor a cont FT A
on:________________ _______________
mption: _____ Yes or _ mption: _____ Ye
empt pursuant to th pursuant to th
hall maintain a curren
all include the req all include the r
subcontract
and m
55452.01510\32977834.2
- 28 -
EXHIBIT “F”
PAYMENT AND PERFORMANCE BONDS
DRAFT
55452.01510\32977834.2
- 29 -
PERFORMANCE BOND
KNOW ALL PERSONS BY THESE PRESENTS:
THAT WHEREAS, the City of San Clemente (hereinafter referred to as “City”) has awarded to ____________________, (hereinafter referred to as the “Contractor”) _______________________ an agreement for ______________________________ (hereinafter referred to as the “Project”).
WHEREAS, the work to be performed by the Contractor is more particularly set forth in the Contract Documents for the Project dated ________________, (hereinafter referred to as “Contract Documents”), the terms and conditions of which are expressly incorporated herein by reference; and
WHEREAS, the Contractor is required by said Contract Documents to perform the terms thereof and to furnish a bond for the faithful performance of said Contract Documents.
NOW, THEREFORE, we, _______________, the undersigned Contractor and _____________________________________________ as Surety, a corporation organized and duly authorized to transact business under the laws of the State of California, are held and firmly bound unto the City in the sum of ___________________________ DOLLARS, ($____________), said sum being not less than one hundred percent (100%) of the total amount of the Contract, for which amount well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors and assigns, jointly and severally, firmly by these presents.
THE CONDITION OF THIS OBLIGATION IS SUCH, that, if the Contractor, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and agreements in the Contract Documents and any alteration thereof made as therein provided, on its part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their intent and meaning; and shall faithfully fulfill all obligations including the one-year guarantee of all materials and workmanship; and shall indemnify and save harmless the City, its officers and agents, as stipulated in said Contract Documents, then this obligation shall become null and void; otherwise it shall be and remain in full force and effect.
As a condition precedent to the satisfactory completion of the Contract Documents, unless otherwise provided for in the Contract Documents, the above obligation shall hold good for a period of one (1) year after the acceptance of the work by City, during which time if Contractor shall fail to make full, complete, and satisfactory repair and replacements and totally protect the City from loss or damage resulting from or caused by defective materials or faulty workmanship, Surety shall undertake and faithfully fulfill all such obligations. The obligations of Surety hereunder shall continue so long as any obligation of Contractor remains. Nothing herein shall limit the City’s rights or the Contractor or Surety’s obligations under the Contract, law or equity, including, but not limited to, California Code of Civil Procedure section 337.15.
Whenever Contractor shall be, and is declared by the City to be, in default under the Contract Documents, the Surety shall remedy the default pursuant to the Contract Documents, or shall promptly, at the City’s option:
DRAFToc
d Cont
the undersig the un
__ as Surety, a corpor __ as Surety, a c
of the State of California of the State of Califor
___________________
one hundred percent ( e hundred
d truly to be made, we d truly to be
s and assigns, jointly and assigns, join
OBLIGATION IS SUC
essors or assigns, sha essors or assigns,
form the covenants, c orm the covenants,
ation thereof made as thereof made as
nd in the manner there nd in the manne
nd shall faithfully fulfill a nd shall faithfully fulfi manship; and shall in
n said Contract D n said Contract
remain in fu
en
55452.01510\32977834.2
- 30 -
(1) Take over and complete the Project in accordance with all terms and conditions in the Contract Documents; or
(2) Obtain a bid or bids for completing the Project in accordance with all terms and conditions in the Contract Documents and upon determination by Surety of the lowest responsive and responsible bidder, arrange for a Contract between such bidder, the Surety and the City, and make available as work progresses sufficient funds to pay the cost of completion of the Project, less the balance of the contract price, including other costs and damages for which Surety may be liable. The term “balance of the contract price” as used in this paragraph shall mean the total amount payable to Contractor by the City under the Contract and any modification thereto, less any amount previously paid by the City to the Contractor and any other set offs pursuant to the Contract Documents.
(3) Permit the City to complete the Project in any manner consistent with local, California and federal law and make available as work progresses sufficient funds to pay the cost of completion of the Project, less the balance of the contract price, including other costs and damages for which Surety may be liable. The term “balance of the contract price” as used in this paragraph shall mean the total amount payable to Contractor by the City under the Contract and any modification thereto, less any amount previously paid by the City to the Contractor and any other set offs pursuant to the Contract Documents.
Surety expressly agrees that the City may reject any contractor or subcontractor which may be proposed by Surety in fulfillment of its obligations in the event of default by the Contractor.
Surety shall not utilize Contractor in completing the Project nor shall Surety accept a bid from Contractor for completion of the Project if the City, when declaring the Contractor in default, notifies Surety of the City’s objection to Contractor’s further participation in the completion of the Project.
The Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract Documents or to the Project to be performed thereunder shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Contract Documents or to the Project, including but not limited to the provisions of sections 2819 and 2845 of the California Civil Code.
IN WITNESS WHEREOF, we have hereunto set our hands and seals this _______ day of ______________, 20__).
(Corporate Seal)
Contractor/ Principal
By
Title
DRAFTm
s work p s wor
ess the balan ess the
hich Surety may hich Suret
d in this paragraph s d in this paragr
City under the Contract under the Contra
ly paid by the y paid by th City to
ntract Documents. ct Docum
City may reject any co may reject any
t of its obligations in the s obligations in the
tractor in completing th tractor in comple
of the Project if the City
bjection to Contractor’s ection to Contractor’s
r value received, hereb r value received, here
addition to the terms
shall in any way a shall in any wa
ge, extensio
t, inclu
55452.01510\32977834.2
- 31 -
(Corporate Seal) Surety
By
Attorney-in-Fact
Signatures of those signing for the Contractor and Surety must be notarized and evidence of corporate authority attached.
(Attach Attorney-in-Fact Certificate) Title
The rate of premium on this bond is ____________ per thousand. The total amount of premium charges, $_______________________________.
(The above must be filled in by corporate attorney.)
THIS IS A REQUIRED FORM
Any claims under this bond may be addressed to:
(Name and Address of Surety) ___________________________________________ ___________________________________________
___________________________________________
(Name and Address of Agent or ___________________________________________ Representative for service of
process in California, if different ___________________________________________ from above)
___________________________________________
(Telephone number of Surety and ___________________________________________ Agent or Representative for service
of process in California)
NOTE: A copy of the Power-of-Attorney authorizing the person signing on behalf of the Surety to do so must be attached hereto.DRAFT_____________ _______ _________________ _____________
__________________
__________________ ____
__________________ ____________
______________ _________
and ____________ __________
service
e Power e Pow -of-Attorney au
ed hereto. ed he
55452.01510\32977834.2
- 32 -
Notary Acknowledgment
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.
STATE OF CALIFORNIA
COUNTY OF ______________
On , 20___, before me, _______________________________, Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.
WITNESS my hand and official seal.
Signature of Notary Public
OPTIONAL
Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document.
CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT
Individual
Corporate Officer
Title(s) Title or Type of Document
Partner(s)
Limited
General Number of Pages
Attorney-In-Fact
Trustee(s)
Guardian/Conservator Date of Document
Other:
Signer is representing:
Name Of Person(s) Or Entity(ies)
Signer(s) Other Than Named Above
DRAFTcapa
alf of whic alf of
State of California th State of Califo
NESS my hand and off
OPTIONAL
ot required by law, it may p ot required by law, it may udulent removal and reattac dulent removal and reattac
SIGNER
ed
l
D
AF
55452.01510\32977834.2
- 33 -
PAYMENT BOND
KNOW ALL MEN BY THESE PRESENTS That
WHEREAS, the City of San Clemente (hereinafter designated as the “City”), by action taken or a resolution passed ___________ , 20____has awarded to ________________ hereinafter designated as the “Principal,” a contract for the work described as follows:
_____________________________________________________ (the “Project”); and WHEREAS, the work to be performed by the Principal is more particularly set forth in the Contract Documents for the Project dated __________________ (“Contract Documents”), the terms and conditions of which are expressly incorporated by reference; and WHEREAS, said Principal is required to furnish a bond in connection with said contract; providing that if said Principal or any of its Subcontractors shall fail to pay for any materials, provisions, provender, equipment, or other supplies used in, upon, for or about the performance of the work contracted to be done, or for any work or labor done thereon of any kind, or for amounts due under the Unemployment Insurance Code or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of said Principal and its Subcontractors with respect to such work or labor the Surety on this bond will pay for the same to the extent hereinafter set forth.
NOW THEREFORE, we, the Principal and __________________________ as Surety, are held and firmly bound unto the City in the penal sum of ______________ Dollars ($___________) lawful money of the United States of America, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents.
THE CONDITION OF THIS OBLIGATION IS SUCH that if said Principal, his or its subcontractors, heirs, executors, administrators, successors or assigns, shall fail to pay any of the persons named in Section 9100 of the Civil Code, fail to pay for any materials, provisions or other supplies, used in, upon, for or about the performance of the work contracted to be done, or for any work or labor thereon of any kind, or amounts due under the Unemployment Insurance Code with respect to work or labor performed under the contract, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department or Franchise Tax Board from the wages of employees of the contractor and his subcontractors pursuant to Section 18663 of the Revenue and Taxation Code, with respect to such work and labor the Surety or Sureties will pay for the same, in an amount not exceeding the sum herein above specified.
This bond shall inure to the benefit of any of the persons named in Section 9100 of the Civil Code so as to give a right of action to such persons or their assigns in any suit brought upon this bond.
It is further stipulated and agreed that the Surety on this bond shall not be exonerated or released from the obligation of this bond by any change, extension of time for performance, addition, alteration or modification in, to, or of any contract, plans, specifications, or agreement pertaining or relating to any scheme or work of improvement herein above described, or pertaining or relating to the furnishing of labor, materials, or equipment therefore, nor by any change or modification of any terms of payment or extension of the time for any payment pertaining or relating to any scheme or work of improvement herein above described, nor by any rescission or attempted rescission of the contract, agreement or bond, nor by any conditions precedent or DRAFTin co
shall fail shall
n, upon, for or upon,
labor done thereon labor done t
Code or for any amou Code or for any a
ent Development Depar ent Development Depa
tors with respect to such rs with respe
t hereinafter set forth. inafter s
ncipal and pal and ________ AF
in the penal sum of e penal sum of _
A
________ ____ ) lawful mone RA
nd truly to be made, w nd truly to be ma
assigns, jointly and sev assigns, jointly and
OF THIS OBLIGATIO THIS OBLIGATIO
xecutors, administrator xecutors, admin
Section 9100 of the C Section 9100 of the
in, upon, for or about in, upon, for or about
thereon of any kin thereon of any
ork or labor pe ork or labor p
d paid ov
of e
55452.01510\32977834.2
- 34 -
subsequent in the bond attempting to limit the right of recovery of claimants otherwise entitled to recover under any such contract or agreement or under the bond, nor by any fraud practiced by any person other than the claimant seeking to recover on the bond and that this bond be construed most strongly against the Surety and in favor of all persons for whose benefit such bond is given, and under no circumstances shall Surety be released from liability to those for whose benefit such bond has been given, by reason of any breach of contract between the owner or City and original contractor or on the part of any obligee named in such bond, but the sole conditions of recovery shall be that claimant is a person described in Section 9100 of the Civil Code, and has not been paid the full amount of his claim and that Surety does hereby waive notice of any such change, extension of time, addition, alteration or modification herein mentioned and the provisions of sections 2819 and 2845 of the California Civil Code.
IN WITNESS WHEREOF, we have hereunto set our hands and seals this _______ day of ______________, 20__.
(Corporate Seal)
Contractor/ Principal
By
Title
(Corporate Seal) Surety
By
Attorney-in-Fact
Title
Signatures of those signing for the Contractor and Surety must be notarized and evidence of corporate authority attached. A Power-of-Attorney authorizing the person signing on behalf of the Surety to do so must be attached hereto.
NOTE: A copy of the Power-of-Attorney authorizing the person signing on behalf of the Surety to do so must be attached hereto.
DRAFTctor/ Principal ctor/ Pri
FT
Title AFSurety
By
signing for the Contra
tached. A Power tached. A Pow
t be attached
of A
55452.01510\32977834.2
- 35 -
Notary Acknowledgment
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.
STATE OF CALIFORNIA
COUNTY OF ______________
On , 20___, before me, _______________________________, Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.
WITNESS my hand and official seal.
Signature of Notary Public
OPTIONAL
Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document.
CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT
Individual
Corporate Officer
Title(s) Title or Type of Document
Partner(s)
Limited
General Number of Pages
Attorney-In-Fact
Trustee(s)
Guardian/Conservator Date of Document
Other:
Signer is representing:
Name Of Person(s) Or Entity(ies)
Signer(s) Other Than Named Above
DRAFTwithi
d capacit d ca
ehalf of which ehalf of
he State of California th he State of Californi
WITNESS my hand and ESS my h
OPTIONAL OPTION
s not required by law, it ma ot required by law, it ma
fraudulent removal and rea ent removal and rea
BY SIGNER D
A
55452.01510\32977834.2
- 36 -
EXHIBIT “G”
FEDERAL REQUIREMENTS
N/A
55452.01510\32977834.2
- 37 -
EXHIBIT “H”
INSURANCE REQUIREMENTS
3.13 Insurance.
3.13.1 Time for Compliance. Contractor shall not commence work under this Contract until it has provided evidence satisfactory to the City that it has secured all insurance required under this section. In addition, Contractor shall not allow any subcontractor to commence work on any subcontract as required in section 1.1.12 of this agreement.
3.13.2 Types of Insurance Required. As a condition precedent to the effectiveness of this Contract for work to be performed hereunder, and without limiting the indemnity provisions of the Contract, the Contractor, in partial performance of its obligations under such Contract, shall procure and maintain in full force and effect during the term of the Contract the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Contractor agrees to amend, supplement or endorse the policies to do so. (A) Commercial General Liability: Commercial General Liability Insurance which affords coverage at least as broad as Insurance Services Office "occurrence" form CG 0001, or the exact equivalent, and shall be no less than $1,000,000 per occurrence and no less than $2,000,000 in the general aggregate. Defense costs shall be paid in addition to the limits.
The policy shall contain no endorsements or provisions limiting coverage for (1) contractual liability; (2) cross liability exclusion for claims or suits by one insured against another; or (3) contain any other exclusion contrary to the Contract.
(B) Automobile Liability Insurance: Automobile Liability Insurance with coverage at least as broad as Insurance Services Office Form CA 0001 covering "Any Auto" (Symbol 1), or the exact equivalent, covering bodily injury and property damage for all activities shall be in an amount of not less than $1,000,000 combined limit for each occurrence. (C) Workers' Compensation: Workers' Compensation Insurance, as required by the State of California and Employer's Liability Insurance with a limit of not less than $1,000,000 per accident for bodily injury and disease.
(D) Not Used.
(E) Contractors Pollution Liability: Not used.
3.13.3 Endorsements. Required insurance policies shall contain the following provisions, or Contractor shall provide endorsements on forms approved by the City to add the following provisions to the insurance policies:
(A) Commercial General Liability
(1) Additional Insured: The City, its officials, officers, employees, agents, and volunteers shall be additional insureds with regard to liability and defense of suits or claims arising out of the performance of the Contract.
DRAFTons
f the Cont f the
urance requirem urance r
policies to do so. policies to do
y: Commercial Gene
surance Services Offic urance Serv
less than $1,000,000 than $1,
Defense costs shall be Defense costs s
nts or provisions limiti s or provisions lim
or claims or suits by o ms or suits by o
y to the Contract.
bile Liability Insuranc bile Liability Insuran
as Insurance Service s Insurance Service
equivalent, covering bo equivalent, co
of not less than $1,000, of not less than $1
Workers' Compen Workers' Com
ornia and Emp ornia and Em
or bodily i
55452.01510\32977834.2
- 38 -
Additional Insured Endorsements shall not (1) be restricted to "ongoing operations"; (2) exclude "contractual liability"; (3) restrict coverage to "sole" liability of Contractor; or (4) contain any other exclusions contrary to the terms of purposes of this Contract.
For all policies of Commercial General Liability insurance, Contractor shall provide endorsements in the form of ISO CG 20 10 10 01 and 20 37 10 01 (or endorsements providing the exact same coverage) to effectuate this requirement.
(2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (B) Automobile Liability:
(1) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (C) Workers' Compensation:
(1) Waiver of Subrogation: A waiver of subrogation stating that the insurer waives all rights of subrogation against the City, its officials, officers, employees, agents and volunteers.
(2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium.
3.13.4 Primary and Non-Contributing Insurance. All policies of Commercial General Liability, Automobile Liability insurance (if required) shall be primary and any other insurance, deductible, or self-insurance maintained by the City, its officials, officers, employees agents or volunteers shall not contribute with this primary insurance. Policies shall contain or be endorsed to contain such provisions.
3.13.5 Waiver of Subrogation. All policies of Commercial General Liability, Automobile Liability insurance (if required) shall contain or be endorsed to waive subrogation against the City, its officials, officers, employees, agents, and volunteers or shall specifically allow Contractor or others providing insurance evidence in compliance with these specifications to waive their right of recovery prior to a loss. Contractor hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subcontractors.
3.13.6 Deductibles and Self-Insured Retentions. Any deductible or self-insured retention in excess of $5,000 must be approved in writing by the City and shall protect the City, its officials, officers, employees, agents and volunteers in the same manner and to the same extent as they would have been protected had the policy or policies not contained a deductible or self-insured retention.
3.13.7 Evidence of Insurance. The Contractor, concurrently with the execution of the Contract, and as a condition precedent to the effectiveness thereof, shall deliver either certified copies of the required policies, or original certificates on forms approved by the City, together with DRAFT g
polic
cancellatio canc
ment of premium ment of p
ation: A waiver of sub waiv
st the City, its officials, City, its
ation: Required insuran Required insuran
(30) day written notice
ll be allowed for non ll be allowed for n -pa
Non-Contributing Insu DR
bility insurance (if requ ility insurance
urance maintained by t urance maintained
contribute with this prim contribute with this pri
sions.
Subrogati
d) shD
55452.01510\32977834.2
- 39 -
all endorsements affecting each policy. Required insurance policies shall not be in compliance if they include any limiting provision or endorsement that has not been submitted to the City for approval. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf. At least fifteen (15 days) prior to the expiration of any such policy, evidence of insurance showing that such insurance coverage has been renewed or extended shall be filed with the City. If such coverage is cancelled or reduced, and not replaced immediately so as to avoid a lapse in the required coverage, Contractor shall, within ten (10) days after receipt of written notice of such cancellation or reduction of coverage, file with the City evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies.
3.13.8 Failure to Maintain Coverage. In the event any policy of insurance required under this Contract does not comply with these specifications or is canceled and not replaced immediately so as to avoid a lapse in the required coverage, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Contractor or City will withhold amounts sufficient to pay premium from Contractor payments. In the alternative, City may cancel this Contract, effective upon notice.
3.13.9 Acceptability of Insurers. Each such policy shall be from a company or companies with a current A.M. Best's rating of no less than A- VII and authorized to transact business of insurance in the State of California, or otherwise allowed to place insurance through surplus line brokers under applicable provisions of the California Insurance Code or any federal law.
3.13.10 Enforcement of Contract Provisions (non estoppel). Contractor acknowledges and agrees that actual or alleged failure on the part of the City to inform Contractor of non-compliance with any requirement imposes no additional obligation on the City nor does it waive any rights hereunder.
3.13.11 Requirements Not Limiting. Requirement of specific coverage or minimum limits contained in this Appendix are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance.
3.13.12 Insurance for Subcontractors. Contractor shall include all Subcontractors as additional insureds under the Contractor's policies, or the Contractor shall be responsible for causing Subcontractors to purchase the appropriate insurance in compliance with the terms of these Insurance Requirements, including adding the City, its officials, officers, employees, agents and volunteers as additional insureds to the Subcontractor's policies. All policies of Commercial General Liability insurance provided by Subcontractors shall be endorsed to name the City, its officials, officers, employees, agents and volunteers as additional insureds using endorsement form ISO CG 20 38 04 13. Contractor shall not allow any Subcontractor to commence work until it has received satisfactory evidence of Subcontractor’s compliance with all insurance requirements under this Contract, to the extent applicable. The Contractor shall provide satisfactory evidence of compliance with this section upon request of the City.
DRAFTha
m paid
cient to pay p cient to
ct, effective upon n t, effective
policy shall be from a co icy shall be from a
A- VII and authorized
se allowed to place insu owed to p
alifornia Insurance Cod alifornia Insura
Contract Provisions ntract Provisions RA
l or alleged failure on th or alleged failure on th
rement imposes no add rement imposes n
uirements Not Limiting ents Not Limiting DR
Appendix are not inten Appendix are no
ver of any coverage no ver of any coverage n
ce for Subcontr ce for Subcon
r the Cont
urchasD