CITY OF SAN MARINO BID AND CONTRACT DOCUMENTS
CITY OF SAN MARINO CONTRACTOR AGREEMENT
MULTI-YEAR SIDEWALK REPLACEMENT PROGRAM PROJECT NO. 22-9272 This City of San Marino Contractor Agreement (Agreement") is made and entered into for the above referenced Project by between of San Marino ("Agency").
CJ Concrete Construction, Inc. ("Contractor") on the 14th day of October, 2022.
In consideration of the mutual covenants and agreements set forth herein, Agency and Contractor have mutually agreed as follows:
1. CONSTRUCTION
The Contractor agrees to do all the Work in connection with the Multi-year Sidewalk Replacement Program Project No. 22-9272 to be constructed at various locations in the City of San Marino, California, including to furnish any and all labor, services, materials and equipment to construct and complete the Project, and appurtenant work in connection therewith, said work to be done and materials to be furnished in strict conformity with the Contract Documents, including but not limited to this Agreement, approved Change Orders, Notice Inviting Bids, Instructions to Bidders, Bidder's Proposal and Information Required for Bid Submittal, Bid Schedules, Addenda and/or Bulletins, plans, Special Provisions (Specifications), General Conditions, General Provisions, Greenbook 202l as amended and supplemented, technical references, all other referenced documents, all codes, permit conditions and regulations, for the total amounts) and any unit prices and additive/deductive items, including all work, labor, services, materials and equipment described and reasonably inferable from documents enumerated in Exhibit "A" attached hereto and incorporated herein by reference (such construction and furnishing of labor, service, materials and equipment hereinafter referred to as the "Work") in a good workmanlike manner according to any and all applicable best practices to the satisfaction of the Agency. The term Contract Documents shall mean this Agreement, and all of the items enumerated in Exhibit "A" and all change orders or addenda issued by the Agency with respect thereto. Agency must consent in writing to any changes in the scope of Work. Exhibit "A" shall be deemed revised in accordance with any revisions for which Agency's consent has been issued. Any revisions to the scope of Work for which Agency's written consent has not provided shall be null and void and done at the risk and sole expense of the Contractor.
2. CONTRACT PRICE
be made in the manner described in the Special Provisions.
Agency may adjust compensation for the Services based on the year to year (March to March) Engineering News Record (ENR) Construction Cost Index (CCI) percentage change with a maximum increase of 5%
3. TERM
The term of this Agreement is from the Effective Date, October 14, 2022 through June 30, 2027.
Issued 3-22-2022 C-1 Project No. 22-9272
Agency may exercise up to two (2) I-year extensions contingent on an annual appropriation of a budget by the City Council and Contractor's satisfactory performance of Contractor's Work as documented by the City Engineer.
4. TIME FOR PERFORMANCE
Time is of the essence in Contractor's performance of the Work for this Agreement. Contractor agrees to any ex pursue the performance and completion of the Work ine ery drei to the Natic color ced.
All timing requirements shall be strictly adhered to unless otherwise modified by the Agency in accordance with the Bid and Contract Documents.
Prior to execution of the Agreement, the State of California declared a state of emergency and issued a stay at home order in connection with the COVID-19 pandemic, and the County of Los Angeles ("'County") issued numerous orders relating to COVID-19, including without limitation an Order to Shelter in Place, originally dated March 17, 2020 (as subsequently extended and amended, including after the date of the Agreement, the "County Order"). In no event shall Contractor be entitled to any additional compensation in connection with any delay or costs associated with the COVID 19 pandemic, the County Order, or any other governmental requirements or regulations in connection therewith, whether currently existing or hereinafter enacted. In the event of any conflict between the terms of this Section and any other provision of the Agreement, in all events, the terms of this Section shall control.
5. DELAYS AND EXTENSIONS OF TIME
Delays and extensions of time will be handled by Agency and Contractor pursuant to the provisions of Section 6-4 of the Special Provisions. However, Contractor must comply with the written notice requirement, as well as timely report back-up information, in strict compliance with the requirements of the provisions of Section 6-4 of the Special Provisions; Contractor's failure to submit these items within the times specified will constitute a waiver of the extension of time and payment for delay and will be ground for refusal by the Agency to consider such request.
LABOR CODE REQUIREMENTS
Pursuant to Labor Code Section 177l.I, the Contractor and all subcontractors shall be registered with the Department of Industrial Relations. Pursuant to Labor Code Section 1771.4, the Contractor is hereby notified that this Project is subject to compliance monitoring and enforcement by the Department of Industrial Relations. Contractor, and any subcontractor engaged by Contractor, must pay not less than the specified prevailing rate of per diem wages to all workers employed in the execution of the contract. (Labor Code § 1774) Contractor is responsible for compliance with Labor Code section 1776 relative to the retention and inspection of payroll records.
Contractor must comply with all provisions of Labor Code section 1775. Under Section 1775, Contractor may forfeit as a penalty to City up to $50.00 for each worker employed in the execution of the Contract by Contractor or any subcontractor for each calendar day, or portion thereof, in which the worker is paid less than the prevailing rates. Contractor may also be liable to pay the difference between the prevailing wage rates and the amount paid to each worker for each calendar day, or portion thereof, for which each worker was paid less than the prevailing wage rate.
Contractor acknowledges and agrees to abide by the provisions of California Labor Code §5 1720, et seq., as well as 177l, 1773, 1773.1, 1773.2, 1773.6, 1773.7, 1774, 1775 1776 and 1777, pertaining to the obligation to pay prevailing wages with respect to the performance of work ("Prevailing Wage Laws").
Contractor shall defend, indemnify, and hold the City, its elected officials, officers, employees, and agents Issued 3-22-2022 C-2 Project No. 22-9272
free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws.
Contractor acknowledges that under California Labor Code sections 1810 et seq., eight hours of labor constitutes a legal day's work. Contractor will forfeit as a penalty to City the sum of $25.00 for each worker employed in the execution of this Contract by Contractor or any subcontractor for each calendar day during which such worker is required or permitted to work more than 8 hours in any one calendar day and 40 hours in any one calendar week in violation of the provisions of Labor Code section 1810. (Labor Code § 1813.)
7. NON-DISCRIMINATION
Contractor, its officers, agents, employees, and subcontractors may not discriminate in the employment of persons to perform the Work because of the race, religion, creed, color, national origin, ancestry, physical handicap, medical condition, marital status, sex or age of such person, except as may be permitted by California Government Code section 12940. Contractor is responsible for compliance with this section.
8. AUTHORIZED AGENCY REPRESENTATIVES
On behalf of the Agency, the City Engineer of the City of San Marino shall be the Agency's authorized representative in the interpretation and enforcement of all Work performed in connection with this Agreement. The City Engineer may delegate authority in connection with this Agreement to his/her assigned designees.
INDEMNIFICATION
Contractor agrees to indemnify, defend and hold harmless City, its elected officials, officers, employees and agents from and against, any and all liabilities, claims, actions, causes of action, proceedings, suits, damages, judgments, liens, levies, costs and expenses of whatever nature, including reasonable attorneys' fees and disbursements (collectively, "Claims"), which City may suffer or incur or to which City may become subject by reason of or arising out of any injury to or death of any person(s), damage to property, loss of use of property, economic loss or otherwise occurring as a result of any negligent or willfully wrongful acts or omissions of Contractor, its officers, employees, agents, or subcontractors committed in performing any Work under this Contract, excluding Claims occurring as a result of the City's sole negligence or willful acts or omissions.
If any action or proceeding is brought against City by reason of any of the matters against which Contractor has agreed to indemnify City as provided above, City need not have first paid for any of the matters to which City is entitled to indemnification in order to be so indemnified. In the event of any Claim made against City, City may, in its sole discretion, reserve, retain or apply any funds due to Contractor under this Contract for the purpose of resolving such Claim. The provisions of this section will survive the expiration or earlier termination of this Agreement.
10. CLAYTON AND CARTWRIGHT ACT ASSIGNMENTS. In entering into this Contract or a contract with a subcontractor to supply goods, services, or materials pursuant to this Contract for the Project, Contractor and any or subcontractor is deemed to have offered and agreed to assign to City all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Sec. 15) or under the Cartwright Act (Chapter 2, commencing with Section 16700 of Part 2 of Division 7 of the California Business and Professions Code), arising from purchases of goods, services, or materials for the Project. This assignment will be deemed made and will become effective at the time City tenders final payment to Contractor, without further acknowledgement by the Parties.
Issued 3-22-2022 C-3 Project No. 22-9272
INSURANCE
Contractor agrees to have and maintain in full force and effect during the term of this Agreement the insurance coverages listed in Exhibit "C" ("Insurance"), which is made a part of this Agreement.
Further, by signing below Contractor certifies that he/she/it is aware of the provisions of Section 3700 of the Labor Code, which requires every employer to be insured against liability for Workers Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Work of this Agreement. Additionally, Contractor shall require each subcontractor to comply with the requirements of Section 3700 of the Labor Code, including requiring each subcontractor to execute the following certification:
"I am aware of the provisions of Section 3700 of the Labor Code, which requires every employer to be insured against liability for worker's compensation or to undertake self-insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the Work of this Agreement."
12. ENTIRE AGREEMENT; CONFLICT
The Contract Documents comprise the entire agreement between the Agency and the Contractor with respect to the Work. In the event of conflict between the terms of this Agreement and the bid of the Contractor, then this Agreement shall control and nothing herein shall be considered as an acceptance of the terms of the bid conflicting herewith.
13. PROJECT DOCUMENTATION
All data, drawings, maps, models, notes, books, documents, papers, daily reports, schedules, time and materials tickets, employee time sheets, accounting records and other evidence pertaining to costs incurred, photographs, reports, studies and other documents (collectively, "Project Documents") prepared, developed or discovered by Contractor in the course of performing any of the Work under this Contract will become the sole property of City. Upon the expiration or termination of this Contract, Contractor must turn over all original Project Documents to City in its possession, but may retain copies of any of the Project Documents it may desire.
Contractor shall maintain the Project Documents and shall make such materials available at its office at all reasonable times during the term of this Agreement and for three (3) years from the date of final payment under this Agreement any documents not turned over to Agency for inspection by Agency.
14. FALSE CLAIMS
Contractor acknowledges that if a false claim is submitted to the Agency, it may be considered fraud and Contractor may be subject to criminal prosecution. Contractor acknowledges that the False Claims Act, California Government Code sections |2650, et seq., provides for civil penalties where a person knowingly submits a false claim to a public entity. These provisions include within their scope false claims made with deliberate ignorance of the false information or in reckless disregard of the truth or falsity of the information. In the event the Agency seeks to recover penalties pursuant to the False Claims Act, it is entitled to recover its litigation costs, including attorneys' fees. Contractor hereby acknowledges that the filing of a false claim may the Contractor to an administrative debarment proceeding wherein Contractor may be prevented from further bidding on public contracts for a period of up to five (5) years.
Issued 3-22-2022 C-4 Project No. 22-9272
I have read and understood all of the provisions of this Section 13, above:
J5 J.5.
(Initial) (Initial)
15. INDEPENDENT CONTRACTOR
Contractor is and will at all times remain as to City a wholly independent contractor and shall not be an employee, agent, partner or joint venturer of the Agency. Agency shall have the right to control Contractor insofar as the results of Contractor's services rendered pursuant to this Agreement; however, Agency shall not have the right to control the means by which Contractor accomplishes such services.
Neither the City nor any of its officers, employees, or agents will have control over the conduct of Contractor or any of Contractor's officers, employees, agents or subcontractors, except as expressly set forth in the Contract Documents. Contractor may not at any time or in any manner represent that it or any of its officers, employees, agents, or subcontractors are in any manner officers, employees, agents or subcontractors of City.
16. LICENSES AND PERMITS
Contractor must, at Contractor's sole expense, obtain all necessary permits and licenses required for the Work, and give all necessary notices and pay all fees and taxes required by law, including, without limitation, any business license tax imposed by City. Contractor represents and declares to Agency that it has all licenses, permits, qualifications and approvals of whatever nature which are legally required to bractice its profession. In performing the Work, Contractor must comply with all applicable statutes aws and regulations, including, but not limited to, OSHA requirements and the San Marino Municipa Code.
17. GENERAL PROVISIONS
a) Authority to Execute. Each Party represents and warrants that all necessary action has been taken by such Party to authorize the undersigned to execute this Contract and to bind it to the performance of its obligations.
Assignment. Contractor may not assign this Contract without the prior written consent of City, which consent may be withheld in the City's sole discretion since the experience and qualifications of Contractor were material considerations for this Contract. c) Binding Effect. This Agreement is binding upon the heirs, executors, administrators, successors and permitted assigns of the Parties.
Integrated Contract. This Contract, including the Contract Documents, is the entire, complete, final and exclusive expression of the Parties with respect to the Work to be performed under this Contract and supersedes all other agreements or understandings, whether oral or written, between Contractor and City prior to the execution of this Contract. e) Modification of Contract. No amendment to or modification of this Contract will be valid unless made in writing and approved by Contractor and by the City Council or City Manager, as applicable.
The Parties agree that this requirement for written modifications cannot be waived and that any attempted Counterparts and Facsimile Signatures. This Contract may be executed in several counterparts, each of which will be deemed an original, and all of which, when taken together, constitute Issued 3-22-2022 C-5 Project No. 22-9272
one and the same instrument. Amendments to this Contract will be considered executed when the signature of a party is delivered by facsimile transmission. Such facsimile signature will have the same effect as an original signature.
Waiver. Waiver by any Party of any term, condition, or covenant of this Contract will not constitute a waiver of any other term, condition, or covenant. Waiver by any Party of any breach of the provisions of this Contract will not constitute a waiver of any other provision, or a waiver of any subsequent breach or violation of any provision of this Contract. Acceptance by City of any Work performed by Contractor will not constitute a waiver of any of the provisions of this Contract.
Interpretation. This Contract will be interpreted, construed and governed according to the laws of the State of California. Each party has had the opportunity to review this Contract with legal counsel. The Contract will be construed simply, as a whole, and in accordance with its fair meaning. It will not be interpreted strictly for or against either party. i) Severability. If any term, condition or covenant of this Contract is declared or determined by any court of competent jurisdiction to be invalid, void or unenforceable, the remaining provisions of this Contract will not be affected and the Contract will be read and construed without the invalid, void or unenforceable provision.
Venue. In the event of litigation between the Parties, venue in state trial courts will be in the County of Los Angeles. In the event of litigation in a U.S. District Court, venue will be in the Central District of California, in Oakland.
IN WITNESS WHEREOF this Agreement is executed as of the date first written above.
AGENCY: CONTRACTOR:
CJ concrete construction, Inc.
le t
By:
Acting City Manage Name: John e. sarno
Its: president
By. Name John c: samo
secretary
City Clerk Contractor's City Business License No.
720989 A
APPROVED AS TO FORM: State Contractor License No. & Class By: 1000002|54
Joe Montes,
DIR Registration No. & Exp
10147 shoemaker Are. Santa fe springs
Street Address CAp 90070
Issued 3-22-2022 C-6 Project No. 22-9272
EST. 1993
CJ CONCRETE CONSTRUCTION, INC. Contractors Licenso. # 720989.4 10142 Shoemaker Ave. • Santa Fe Springs, CA 90670 • Ph. (562) 777-2222 • Fax (562) 777-2220
MINUTES OF MEETING OF THE BOARD OF DIRECTORS TAKEN BY
UNANIMOUS WRITTEN CONSENT OF CJ CONCRETE CONSTRUCTION, INC.
A California Corporation
The undersigned, all being directors of CJ Concrete Construction, Inc. a California Corporation, acting in accordance with bylaws of the corporation and taking said action without a formal meeting to hereby adopt the following resolutions:
BE IT THEREFORE RESOLVED THAT 1) John C. Sarno, President, 2) John C.
Sarno, Secretary and 3) John C. Sarno, Treasurer is hereby authorized to execute to contracts and other legal instruments and to bind said corporation accordingly as is appropriate.
BEIT THEREFORE RESOLVED further that the signature of above will bind the above corporation.
IN WITNESS THEREOF, the undersigned, being all the directors of the corporation, has executed the Consent effective as of this 2"d day of February 2020.
Board of Directors:
Dated 8/9|2071
John C. Sarno, Sole member of the Board of Directors
santafe springs cA golzo
City, State, Zip Code
[NOTE: In the event the Contractor is a Corporation, the signatures of two separate persons holding different offices must be provided.]
Issued 3-22-2022 C-7 Project No. 22-9272
EXHIBIT A
CONTRACT DOCUMENTS
See "Multi-Year Sidewalk Replacement Program Project No. 22-9272" contract documents, including project plans and specifications approved by the San Marino City Council on May 11, 2022, and incorporating all Addenda issued.
Issued 3-22-2022 C-8 Project No. 22-9272
EXHIBIT B
CONTRACT PRICE
The Contract Price for performing all Work described in the Contract Documents, including labor, materials, services and equipment is the total amount of all lump sum items and of all unit price sums, determined by nultiplying the unit price for each item times the actual quantity of each such item, as determined b the Agency. See next page for quantities and unit prices/ Issued 3-22-2022 C-9 Project No. 22-9272
EXHIBIT C
INSURANCE
1. General Requirements. Contractor must procure and maintain in full force and effect during the term of this Contract the following types of insurance with coverage limits complying, at a minimum, with the limits set forth below:
Type of Insurance Limits (combined single)
Commercial General Liability $5,000,000
Business Automobile Liability $5,000,000
Workers' Compensation $1,000,000
Builder's Risk Completed value of the project
Surety Bonds As described below
Professional Liability $1,000,000
Contractors' Pollution Legal Liability $1,000,000
If the contractor maintains higher limits than the minimums shown above, the City requires and shall be entitled to coverage for the higher limits maintained by the contractor. Any available insurance proceeds in excess of the specific minimum limits of insurance and coverage shall be available to the City.
2. Commercial General Liability Insurance. Insurance Services Office Form CG 00 01 covering CGL on an "occurrence" basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $5,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location or the general aggregate limit shall be twice the required occurrence limit.
3. Business Auto Coverage. Insurance Services Office Form Number CA 0001 covering Code 1 (any auto), with limits no less than $5,000,000 per accident for bodily injury and property damage. If Contractor or Contractor's employees will use personal autos in any way on this Project, Contractor must provide evidence of personal auto liability coverage for each such person.
4. Workers Compensation. Insurance as required by the State of California, with Statutory Limits, and Employers' Liability insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.
5. Builder's Risk (Course of Construction). Insurance utilizing an "All Risk" (Special Perils) coverage form, with limits equal to the completed value of the project and no coinsurance penalty provisions. Contractor may submit evidence of Builder's Risk insurance in the form of Course of Construction coverage. Such coverage shall name the City as a loss payee as their interest may appear.
6. Surety Bonds. Contractor shall provide the following Surety Bonds: (1) Bid bond, (2) performance bond, (3) payment bond, and (4) maintenance bond. The Payment Bond and the Performance Bond shall be in a sum equal to the contract price. If the Performance Bond provides for a one-year warranty a separate Maintenance Bond is not necessary. If the warranty period specified in the contract is for longer than one year a Maintenance Bond equal to 10% of the contract price is Issued 3-22-2022 C-10 Project No. 22-9272
required. Bonds shall be duly executed by a responsible corporate surety, authorized to issue such bonds in the State of California and secured through an authorized agent with an office in California.
7. Professional Liability. If design/build, with limits no less than $1,000,000 per occurrence or claim, and $2,000,000 policy aggregate.
8. Contractors' Pollution Legal Liability and/or Asbestos Legal Liability and/or Errors and Omissions (if project involves environmental hazards) with limits no less than $1,000,000 per occurrence or claim, and $2,000,000 policy aggregate.
9. Other Insurance. Contractor may be required to obtain such other insurance coverage as may be required by applicable law or by the City.
10. Excess or Umbrella Liability Insurance (Over Primary). If an excess or umbrella liability policy is used to meet limit requirements, the insurance must provide coverage at least as broad as specified for the underlying coverages. Any such coverage provided under an excess or umbrella liability policy must include a "drop down provision" providing primary coverage above a maximum $25,000 self- insured retention for liability not covered by primary but covered by the umbrella. Coverage must be provided on a "pay on behalf' basis, with defense costs payable in addition to policy limits. There must be no cross-liability exclusion precluding coverage for claims or suits by one insured against another. Coverage must be applicable to City for injury to employees of Contractor, its subcontractors or others performing work to satisfy Contractor's obligations under this Contract.
The scope of coverage provided is subject to approval of City following receipt of proof of insurance as required herein. Limits are subject to review, but in no event may be less than $2,000,000 per occurrence and aggregate.
II. Certificates of Insurance and Endorsements. Prior to commencing any Work under this Contract, Contractor must file with the Director Certificates of Insurance and Endorsements evidencing the existence of all insurance required by this Contract, along with such other evidence of insurance or copies of policies as may reasonably be required by City. Such Certificates of Insurance and Endorsements must be in a form approved by the City Attorney of City. Contractor must maintain current certificates and endorsements on file with City during the term of this Contract reflecting the existence of all required insurance. Each of the certificates must expressly provide that no material change in the policy, or termination thereof, will be effective except upon 30 days prior written notice to City. The City reserves the right to require complete, certified copies of the insurance certificates and endorsements.
12. Accessibility of Insurers. Insurance is to be placed with insurances with a current A.M. Best rating of no less than A: VIl, unless otherwise acceptable to the City.
13. Waiver of Subrogation. Contractor hereby agrees to waive rights of subrogation which any insurer of Contractor may acquire from Contractor by virtue of the payment of any loss. Contractor agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation. The Workers' Compensation policy shall be endorsed with a waiver of subrogation in favor of the Entity for all work performed by the Contractor, its employees, agents and subcontractors.
Failure to Maintain Required Insurance. If Contractor, for any reason, fails to have in place at all times during the term of this Contract all of the required insurance coverage, the Director may obtain such coverage at Contractor's expense and deduct the cost from the sums due Contractor.
15. Subcontractors. Contractor shall require and verify that all subcontractors maintain insurance meeting all the requirements stated herein, and Contractor shall ensure that Entity is an additional insured on insurance required from subcontractors. For CGL coverage subcontractors shall provide coverage with a format least as broad as CG 20 38 04 13.
Issued 3-22-2022 C-1l Project No. 22-9272
16. Effect of Coverage. The existence of the required insurance coverage under this Contract will not be deemed to satisfy or limit Contractor's indemnity obligations under this Contract. Contractor acknowledges that the insurance coverage and policy limits set forth in this Contract constitute the minimum coverage and policy limits required. Any insurance proceeds available to City in excess of the limits and coverage required by this Contract, and which is applicable to a given loss, must be made available to City to compensate it for such losses.
17. Special Risks or Circumstances. Entity reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other Issued 3-22-2022 C-12 Project No. 22-9272
Bond Number: CAC722081
PAYMENT BOND
(Bond for Labor and Material)
KNOW ALL PERSONS BY THESE PRESENTS:
1.01 THAT WHEREAS, City of San Marino (Owner) has awarded to - CJ Concrete Construction, Inc. _ as Principal, Contract Number 22-9272
dated the 14th _day of October , 2022(
Marino Multi-Year Sidewalk Replacement Program
- which Contract is by this reference made a part hereof, for the work of the following Contract:
Mult/-year Sidewalk Replacement Program Project No. 22-9272 at various location within the City of San Marino
1.02 AND WHEREAS, Principal is required to furnish a bond in connection with the Contract to secure the payment of claims of laborers, mechanics, material suppliers, and other persons as provided by
1.03 NOW, THEREFORE, we, the undersigned Principal and Merchants Bonding Company (Mutual) -, as Surety, are held and firmly bound unto Owner in the sum of 100% OF THE CONTRACT PRICE ($583,300.00 1, for which payment well and truly to be made we bind ourselves, our heirs, executors, administrators, successors, and assigns, jointly and severally, firmly by these presents.
1.04 THE CONDITION OF THIS OBLIGATION IS SUCH, that If Principal, or its executors, administrators, successors, or assigns approved by Owner, or its subcontractors shall fail to pay any of the persons named in California Civil Code Section 9100, or amounts due under the State of Californía Unemployment Insurance Code with respect to work or labor performed under the Contract, or for any amounts required to be deducted, withheld, and paid over to the State of Callfornia Employment Development Department from the wages of employees of Principal and subcontractors pursuant to Section | 3020 of the State of California Unemployment Insurance Code with respect to such work and labor, that Surety will pay for the same in an amount not exceeding the sum specified in this bond, plus reasonable attorneys' fees, otherwise the above obligation shall become and be null and void.
1.06 This bond shall inure to the benefit of any of the persons named in California Civil Code Section 100, as to give a right of action to such persons or their assigns in any suit brought upon this bon he intent of this bond is to comply with the California Mechanic's Lien Lan
1.07 Issued 3-22-2022 C-13 Project No. 22-9272
one or more of them, or against less than all of them without impairing Owner's rights agalnst the other.
1.08 Correspondence or claims relating to this bond shall be sent to Surety at the address set forth below.
IN WITNESS WHEREOF, we have hereunto set our hands this 25thlay of Octob % 22
CONTRACTOR AS PRINCIPAL SURETY
CJ Concrete Construction, Inc. Merchants Bonding Company (Mutual) Company: (Corp, Seal) •ompany: (Corp. Sea!)
Signature
roth c- sarno
Jennifer Castillo
Name Name
president Attorney-in-fact
Title Title
10142 Shoemaker Ave, 7220 N. 16th Street, Bldg K
Street Address Street Address
Santa Fe Springs, CA Phoenix, AZ 85020
City, State, Zip Code City, State, Zip Code
END OF DOCUMENT
Issued 3-22-2022 C-14 Project No. 22-9272
CALIFORNIA ALL- PURPOSE
CERTIFICATE OF ACKNOWLEDGMENT
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.
State of California }
-
County of las Angeles }
On 10-2808 before me, Rachel Andrea jimenez, Notarolic
(Here insert name and title of the officer*
personally appeared John e. sarno
who proved to me on the basis of satisfactory evidence to be the personts) whose name(g) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacityfies), and that by his/her/their signaturefs) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.
RACHEL ANDREA JIMENEZ
WITNESS my hand and official seal. Notary Public - California Los Angeles County
Commission # 2305370
My Comm. Expires Sep 15, 2023
Notary Public Signature (Notary Public Seal)
INSTRUCTIONS FOR COMPLETING THIS FORM
ADDITIONAL OPTIONAL INFORMATION This form complies with current California statutes regarding notary wording and, DESCRIPTION OF THE ATTACHED DOCUMENT if needed, should be completed and attached to the document. Acknowledgments from other states may be completed for documents being sent to that state so long Paument Rand as the wording does not require the California notary to violate California notary (Title or description of attached document) • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signers) personally appeared which (Title or description of attached document continued) must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her Number of Pages _ Document Date 10:25:00 commission followed by a comma and then your title (notary public). • Print the name(s) of document signers) who personally appear at the time of notarization.
CAPACITY CLAIMED BY THE SIGNER • Indicate the correct singular or plural forms by crossing off incorrect forms (i.e. te/she/they, is /are) or circling the correct forms. Failure to correctly indicate this ] Individual (s) information may lead to rejection of document recording. • Corporate Officer • The notary seal impression must be clear and photographically reproducible.
Impression must not cover text or lines. If seal impression smudges, re-seal if a Pesident sufficient area permits, otherwise complete a different acknowledgment form. • Signature of the notary public must match the signature on file with the office of • Partners)
the county clerk.
• Attorney-in-Fact Additional information is not required but could help to ensure this • Trustee(s) acknowledgment is not misused or attached to a different document.
Indicate title or type of attached document, number of pages and date.
Other Indicate the capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary). 2015 Version www. NotaryClasses.com 800-873-9865 • Securely attach this document to the signed document with a staple.
State of Arizona
County of Maricopa
On this 25th day of October, 20_22 _, before me
personally appeared Jennifer Castillo
personally known to me or proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the foregoing instrument and acknowledged to me that he/she/they executed the same in his/her/their capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity on behalf of which the person(s) acted, executed the instrument.
or Teamie Alony
Notary Public
MELANIE ANKENEY Melanie Ankeney
Notary Public, State of Arizonal
Maricopa County My Commission Expires:
Commission # 564826
My Commission Expires July 12, 2023
July 12, 2023
MERCHANTS
BONDING COMPANY™
POWER OF ATTORNEY
bot being corporations of the state of towa hereih lectively called the Companies) hereby make consiste and a da... Know All Persons By These Presents, Chrystal Hedges; David J McKee; Jennifer Castillo; Joseph A Clarken Ill; Melanie Ankeney; Patrick R Hedges; Ted H Rarick their true and lawful Attorneys)-in-Fact, to sign its name as surety(ies) and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law.
is Power-of-Attorney is granted and is signed and sealed by facsimile under and by authority of the following By-Laws adopted by the Boa Directors of Merchants Bonding Company (Mutual) on April 23, 2011 and amended August 14, 2015 and adopted by the Board of Directo of Merchants National Bonding, Inc., on October 16, 2015.
Or Criediton thero aurorang the execution and de lony ory my bond, underating, tec orniance, or ther sure ye hip oligations or may or Certification thereof authorizing
Company, and such signature and seal when so used shall have the same force and effect as though manually fixed." In connection with obligations in favor of the Florida Department of Transportation only, it is agreed that the power and authority hereby given to the Attorney-in-Fact includes any and all consents for the release of retained percentages and/or final estimates on engineering and construction contracts required by the State of Florida Department of Transportation. It is fully understood that consenting to the State of Florida Department of Transportation making payment of the final estimate to the Contractor and/or its assignee, shall not relieve this surety company of any of its obligations under its bond.
In connection with obligations in favor of the Kentucky Department of Highways only, it is agreed that the power and authority hereby given to the Attomey-in-Fact cannot be modified or revoked unless prior written personal notice of such intent has been given to the Commissioner- Department of Highways of the Commonwealth of Kentucky at least thirty (30) days prior to the modification or revocation.
In Witness Whereof, the Companies have caused this instrument to be signed and sealed this 4th day of September , 2020 NG
ORPO ORPO MERCHANTS BONDING COMPANY (MUTUAL)
MERCHANTS NATIONAL BONDING, INC.
2003 1933 "Larry Taylo
Presiden
*
STATE OF IOWA
COUNTY OF DALLAS ss.
On this 4th day of September 2020 , before me appeared Larry Taylor, to me personally known, who being by me duly sworn did say that he is President of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC.; and that the seals affixed to the foregoing instrument are the Corporate Seals of the Companies; and that the said instrument was signed and sealed in behalf of the Companies by authority of their respective Boards of Directors.
SARIAL POLLY MASON
2 Commission Number 750576 Polly mason
My Commission Expires
OwP January 07, 2023 Notary Public
Loes at mana is ostument)
William Warner, Jr., Secretary of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC., do here ertify that the above and foregoing is a true and correct copy of the POWER-OF-ATTORNEY executed by said Companies, which is still in f force and effect and has not been amended or revoked.
In Witness Whereof, I have hereunto set my hand and affixed the seal of the Companies on this 25th day of October , 2022 ONA
RPOR
William Harmer g.
1933 Secretary
2003
*
POA 0018 (1/20)
Bond Number: CAC722081
CONSTRUCTION PERFORMANCE BOND
amount of L. $583,300.00
plural where applicable.
CONTRACTOR: SURETY
Merchants Bonding Company (Mutual
_ CJ Concrete Construction, Inc.
10142 Shoemaker Ave 6700 Westown Parkway
Address Principal Place of Business
Santa Fe Springs, CA Des Moines, IA 50306
Cley/State/Zip Cry/State/Zip
CONSTRUCTION CONTRACT: [ October 20_, in the amount of L $583, 300.00 /14 ,2022J.
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corp. Seal) Company: (Corp. Seal)
Signature:
John c. sarno Jennifer Castillo
Name: Name:
president Attorney-in-fact
Title: Title:
Issued 3-22-2022 C-15 Project No. 22-9272
CALIFORNIA ALL- PURPOSE
CERTIFICATE OF ACKNOWLEDGMENT
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.
State of California }
County of 105 Angeles }
on 10-28:00 before me, Rachel AndreaJimenez Notary public. (Here insert name and tide of the officer
personally appeared John c: sarno
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the personts), or the entity upon behalf of which the person(6) acted, executed the instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.
RACHEL ANDREA JIMENEZ
WITNESS my hand and official seal. Notary Public - California Los Angeles County
Commission # 2305370
My Comm. Expires Sep 15, 2023
Notary Public Signature (Notary Public Seal)
INSTRUCTIONS FOR COMPLETING THIS FORM
ADDITIONAL OPTIONAL INFORMATION This form complies with current California statutes regarding notary wording and, DESCRIPTION OF THE ATTACHED DOCUMENT if needed, should be completed and attached to the document. Acknowledgments from other states may be completed for documents being sent to that state so long as the wording does not require the California notary to violate California notary performance Band
(Title or description of attached document) • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signers) personally appeared which (Title or description of attached document continued) must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her Number of Pages Document Date 10:25:0a commission followed by a comma and then your title (notary public). • Print the name(s) of document signers) who personally appear at the time of CAPACITY CLAIMED BY THE SIGNER •Indicate the correct singular or plural forms by crossing off incorrect forms (i.e. he/she/they, is /are) or circling the correct forms. Failure to correctly indicate this • Individual (s) information may lead to rejection of document recording. • Corporate Office • The notary seal impression must be clear and photographically reproducible.
President Impression must not cover text or lines. If seal impression smudges, re-seal if a (Title) sufficient area permits, otherwise complete a different acknowledgment form. • Signature of the notary public must match the signature on file with the office of • Partner(s)
the county clerk.
• Attorney-in-Fact Additional information is not required but could help to ensure this Trustee(s) acknowledgment is not misused or attached to a different document.
Indicate title or type of attached document, number of pages and date. • Other Indicate the capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary). 2015 Version www.NotaryClasses.com 800-873-9865 • Securely attach this document to the signed document with a staple.
State of Arizona
County of Maricopa
On this 25th day of October, 20_ 22 , before me
personally appeared Jennifer Castillo
personally known to me or proved to me on the basis of satisfactory evidence to be the person(s) whose names) is/are subscribed to the foregoing instrument and acknowledged to me that he/she/they executed the same in his/her/their capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity on behalf of which the person(s) acted, executed the instrument.
ex. melanies Anhany
Notary Public
Melanie Ankeney
My Commission Expires:
July 12, 2023
CITY OF SAN MARINO
Name Multi-Year Sidewalk Replacement Program
Proj. No. 22-9272
Bid Bidder # 1: CJ Concrete
Opening April 21, 2022 Construction Inc.
Extended
Item Number Item Description Unit Quantity Unit Price
Amount
Mobilization LS 2,500 2,500.00
Concrete Sidewalk, 4-in. Thick (4,752 LF) SF 23,760 12.5 297,000.00 Concrete Sidewalk, 6-in. Thick (528 LF) SF 2,640 39,600.00 Concrete Curb Ramp Ea 6,800 40,800.00
Curb Type A2/8 LF 250 60| 15,000.00
Concrete Driveway Approach SF 1,560 15 23,400.00
TOTAL BASE BID AMOUNT 418,300.00
Additive Bid Item "A" 1 -
A-1 Concrete Sidewalk, 4-in. Thick (1,320 LF) SF 6,600 12.50 82,500.00 Additive Bid Item "B"
B-1 Concrete Sidewalk, 4-in. Thick (1,320) SF 6,600 12.50 82,500.00 TOTAL ADDITIVE 165,000.00
TOTAL BID PRICE 583,300.00
Checked by: Robert Baumar Approved by: Robert Neumar
NOTES
BOND TERMS AND CONDITIONS
I. Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to Owner for the complete and proper performance of the Construction Contract, which is incorporated herein by reference.
2. If Contractor completely and properly performs all of its obligations under the Construction Contract, Surety and Contractor shall have no obligation under this Bond.
3. If there is no Owner Default, Surety's obligation under this Bond shall arise after:
3.1 Owner provides Surety with written notice that Owner has declared a Contractor Default under the Construction Contract pursuant to the terms of the Construction Contract; and
3.2 Owner has agreed to pay the Balance of Contract Sum:
3.2.1 To Surety in accordance with the terms of this Bond and the Construction Contract; or
3.2.2 To a Contractor selected to perform the Construction Contract in accordance with the terms of this Bond and the Construction Contract.
4. When Owner has satisfied the conditions of Paragraph 3 above, Surety shall promptly (within 40 Days) and at Surety's expense elect to take one of the following actions:
4.1 Arrange for Contractor, with consent of Owner, to perform and complete the Construction •ontract (but Owner may withhold consent, in which case the Surety must elect an optio escribed in Paragraphs 4.2, 4.3 or 4.4 below); c
4.2 Undertake to perform and complete the Construction Contract itself, through its agents or through independent contractors or Construction entities; provided, that Surety may not conse Contractor as is agent or independent contractor or Contractor withour Owner s
4.3 Undertake to perform and complete the Construction Contract by obtaining bids fron qualified contractors or Construction entities acceptable to Owner for a contract for erformance and completion of the Construction Contract and, upon determination by Owner of the lowest responsive and responsible Bidder, arrange for a contract to b prepared for execution by Owner and the contractor or Contractor selected with Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract; and, if Surety's obligations defined in Paragraph 6 below, exceed the Balance of Contract Sum, then Surety shall pay to Owner the amount of such excess; or
4.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor or Contractor, and with reasonable promptness under the circumstances and, after investigation and consultation with Owner, determine in good faith its monetary obligation to Owner under Paragraph 6 below, for the performance and completion of the Construction Contract and, as soon as practicable after the amount is determined, tender payment therefor to Owner with full explanation of the payment's calculation. If Owner accepts Surety's tender under this Paragraph 4.4, Owner may still hold Surety liable for future damages then unknown or unliquidated resulting from the Contractor Default, as agreed by Owner and Surety at the time of tender. If Owner disputes the amount of Surety's tender Issued 3-22-2022 C-16 Project No. 22-9272
under this Paragraph 4.4, Owner may exercise all remedies available to it at law to enforce Surety's liability under Paragraphs 6 and 6.3 below.
5. At all times Owner shall be entitled to enforce any remedy available to Owner at law or under the Construction Contract including, without limitation, and by way of example only, rights to perform work, protect Work, mitigate damages, advance critical Work to mitigate schedule delay, and coordinate Work with other consultants or contractors.
6. If Surety elects to act under Paragraphs 4.l, 4.2 or 4.3 above, within the time period provided in Paragraph 4, above, and complies with its obligations under this Bond, Surety's obligations under this Bond are commensurate with Contractor's Construction Contract obligations. Surety's obligations include, but are not limited to:
6.1 Contractor's obligations to complete the Construction Contract and correct Defective
6.2 Contractor's obligations to pay liquidated damages; and
6.3 To the extent otherwise required of Contractor under the Construction Contract, Contractor's obligations to pay additional legal, design professional, and other costs not included within liquidated damages resulting from Contractor Default (but excluding attorney's fees incurred to enforce this Bond).
If Surety does not elect to act under Paragraphs 4.I, 4.2, 4.3, or 4.4, above, within the time period provided in Paragraph 4, above, or comply with its obligations under this Bond, then Surety shall be deemed to be in default on this Bond ten Days after receipt of an additional written notice from Owner to Surety demanding that Surety perform its obligations under this Bond. Such Surety default shall be independent of the Contractor Default. To the extent Surety's independent default causes Owner to suffer damages including, but not limited to, delay damages, which are different from, or in addition to (but not duplicative of) damages which Owner is entitled to receive under the Construction Contract, Surety shall also be liable for such damages. In the event any Surety obligation following its independent default is inconsistent or conflicts with California Civil Code Section 2809, or any other law which either prohibits, restricts, limits or modifies in any way any obligation of a surety which is larger in amount or in any other respect more burdensome than that of the principal, Surety hereby waives the provisions of such laws to that extent.
8. If Surety elects to act under Paragraphs 4.I, 4.3 or 4.4 above, within the time period provided in Pander aphs ondi limited topies ena l obligations under this Bond, Surety's monetary obligation
9. No right of action shall accrue on this Bond to any person or entity other than Owner or its successors or assigns.
10. Surety hereby waives notice of any change, alteration or addition to the Construction Contract or to related subcontracts, design agreements, purchase orders and other obligations, including changes of time, and of any Owner action in accordance with Paragraph 5 above. Surety consents to all terms of the Construction Contract, including provisions on changes to the Contract. No extension of time, change, alteration, Modification, deletion, or addition to the Contract Documents, or of the Work (including services) required thereunder, or any Owner action in accordance with Paragraph 5 above shall release or exonerate Surety on this Bond or in any way affect the obligations of Surety on this Bond, unless such action is an Owner Default.
Issued 3-22-2022 C-17 Project No. 22-9272
Any proceeding, legal or equitable, under this Bond shall be instituted in any court of competent jurisdiction where a proceeding is pending between Owner and Contractor regarding the Construction Contract, or in the Superior Court of the County of Los Angeles, California, or in a court of competent jurisdiction in the location in which the Work is located. Communications from Owner to Surety under Paragraph 3.I above shall be deemed to include the necessary agreements under Paragraph 3.2 above unless expressly stated otherwise.
12. All notices to Surety or Contractor shall be mailed or delivered (at the address set forth on the signature page of this Bond), and all notices to Owner shall be mailed or delivered as provided in Section 1-7.1.10 of the Special Provisions. Actual receipt of notice by Surety, Owner or Contractor, however accomplished, shall be sufficient compliance as of the date received at the foregoing addresses.
13. Any provision in this Bond conflicting with any statutory or regulatory requirement shall be deemed deleted herefrom and provisions conforming to such statutory requirement shall be deemed incorporated herein.
14. Definitions
14.1 Balance of Contract Sum: The total amount payable by Owner to Contractor pursuant to the terms of the Construction Contract after all proper adjustments have been made under the Construction Contract, for example, deductions for progress payments made, and increases/decreases for approved Modifications to the Construction Contract.
14.2 Construction Contract: The agreement between Owner and Contractor identified on the signature page of this Bond, including all Contract Documents and changes thereto.
14.3 Contractor Default: Material failure of Contractor, which has neither been remedied nor waived, to perform or otherwise to comply with the terms of the Construction Contract, limited to "default" or any other condition allowing a termination for cause as provided in Section 6-7.3 of the Special Provisions).
Owner Default: Material failure of Owner, which has neither been remedied nor waived, to pay Contractor progress payments due under the Construction Contract or to perform other material terms of the Construction Contract, if such failure is the cause of the asserted Contractor Default and is sufficient to justify Contractor termination of the Construction Contract.
END OF DOCUMENT
Issued 3-22-2022 C-18 Project No. 22-9272
DATE (MM/DD/YYYY)
'ACORD® CERTIFICATE OF LIABILITY INSURANCE
10/25/2022
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(les) must have ADDITIONAL INSURED provisions or be endorsed.
If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsements).
Behr Insurance Services Inc. No. Ext): 888-988-2347 [AC, No):
A/C
1420 E Los Angeles Ave #203 ADDRESS [email protected] INSURER(S) AFFORDING COVERAGE NAIC #
Simi Valley CA 93065 INSURERA: VALLEY FORGE INS CO 20508 INSURER B: CONTINENTAL CAS CO 20443
INSURED
INSURER C: CONTINENTAL INS CO 35289
CJ Concrete Construction Inc
10:42 SHOEMAKER AVE INSURER D:
INSURER E :
SANTA FE SPRINGS CA 90670-3404 INSURER F:
COVERAGES CERTIFICATE NUMBER: REVISION NUMBER:
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS
TADDLSUBRT OLICY E LIMITS
TYPE OF INSURANCE INSD WVD POLICY NUMBER
X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE 1,000,000 JAMAGE TO RENTE 100,000
] CLAIMS-MADE X OCCUR •REMISES (Ea occurrence
15,000
MED EXP (Any one person
A 7017691303 11/12/2021 11/12/2022 PERSONAL & ADV INJURY 1,000,000 GENERAL AGGREGATE 2,000,000
GEN'L AGGREGATE LIMIT APPLIES PER:
RO PRODUCTS - COMP/OP AGG 2,000,000
X POLICY L EC LOC
OTHER: COMBINED SINGLE LIMT
AUTOMOBILE LIABILITY Ea accident) 1,000,000
X ANY AUTO BODILY INJURY (Per person)
OWNED 7 SCHEDULED 7017691317 11/12/2021 11/12/2022 BODILY INJURY (Per accident)
B AUTOS ONLY AUTOS
HIRED NON-OWNED
AUTOS ONLY AUTOS ONLY
UMBRELLA LIAB X OCCUR EACH OCCURRENCE 4,000,000
7017691320 11/12/2021 11/12/2022 AGGREGATE 4,000,000
C X EXCESS LIAB CLAIMS-MADE
DED X RETENTIONS 10,000
WORKERS COMPENSATION STATUTE
AND EMPLOYERS' LIABILITY Y/ N
ANY PROPRIETOR/PARTNER/EXECUTIVE E.L. EACH ACCIDENT $
N/A
E.L. DISEASE - EA EMPLOYEE S
DESCRIPTION OF OPERATIONS below E.L. DISEASE - POLICY LIMITS DESCRIPTION OF OPERATIONS / LOCATIONS/ VEHICLES (ACORD 101, Additional Remarks Schedule, may be aftached if more space is required) Certificate holder is additional insured when required by contract for General Liability per attached CNA74705XX (1-15) endorsement.
CERTIFICATE HOLDER CANCELLATION
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City of San Marino ACCORDANCE WITH THE POLICY PROVISIONS. 2200 Huntington Drive AUTHORIZED REPRESENTATIVE
Jonathan Behr
1 San Marino CA 91108
© 1988-2015 ACORD CORPORATION. All rights reserved.
ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD CNA
Contractors' General Liability Extension Endorsement
It is understood and agreed that this endorsement amends the COMMERCIAL GENERAL LIABILITY COVERAGE PART as follows. If any other endorsement attached to this policy amends any provision also amended by this endorsement, then that other endorsement controls with respect to such provision, and the changes made by this endorsement with respect to such provision do not apply.
TABLE OF CONTENTS
1. Additional Insureds
2. Additional Insured - Primary And Non-Contributory To Additional Insured's Insurance
3. Bodily Injury - Expanded Definition
4. Broad Knowledge of Occurrence/ Notice of Occurrence
5. Broad Named Insured
6. Broadened Liability Coverage For Damage To Your Product And Your Work
7. Contractual Liability - Railroads
8. Electronic Data Liability
9. Estates, Legal Representatives and Spouses
10. Expected Or Intended Injury - Exception for Reasonable Force
11. General Aggregate Limits of Insurance - Per Project
12. In Rem Actions
13. Incidental Health Care Malpractice Coverage
14. Joint Ventures/Partnership/Limited Liability Companies
15. Legal Liability - Damage To Premises / Alienated Premises / Property In The Named Insured's Care, Custody or Control
16. Liquor Liability
17. Medical Payments
18. Non-owned Aircraft Coverage
19. Non-owned Watercraft
20. Personal And Advertising Injury - Discrimination or Humiliation
21. Personal And Advertising Injury - Contractual Liability
22. Property Damage - Elevators
23. Supplementary Payments
24. Unintentional Failure To Disclose Hazards
25. Waiver of Subrogation - Blanket
26. Wrap-Up Extension: OCIP CCIP, or Consolidated (Wrap-Up) Insurance Programs CNA74705XX (1-15) Policy No: 7017691303
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission. 'CNA
Contractors' General Liability Extension Endorsement
1. ADDITIONAL INSUREDS
a. WHO IS AN INSURED is amended to include as an Insured any person or organization described in paragraphs A. through H. below whom a Named Insured is required to add as an additional insured on this Coverage Part under a written contract or written agreement, provided such contract or agreement:
(1) is currently in effect or becomes effective during the term of this Coverage Part; and (2) was executed prior to:
(a) the bodily injury or property damage; or
(b) the offense that caused the personal and advertising injury, for which such additional insured seeks coverage.
b. However, subject always to the terms and conditions of this policy, including the limits of insurance, the Insurer will not provide such additional insured with:
(1) a higher limit of insurance than required by such contract or agreement; or (2) coverage broader than required by such contract or agreement, and in no event broader than that described by the applicable paragraph A. through H. below.
Any coverage granted by this endorsement shall apply only to the extent permissible by law.
A. Controlling Interest
Any person or organization with a controlling interest in a Named Insured, but only with respect to such person or organization's liability for bodily injury, property damage or personal and advertising injury arising out of:
1. such person or organization's financial control of a Named Insured; or
2. premises such person or organization owns, maintains or controls while a Named Insured leases or occupies such premises;
provided that the coverage granted by this paragraph does not apply to structural alterations, new construction or demolition operations performed by, on behalf of, or for such additional insured.
B. Co-owner of Insured Premises
A co-owner of a premises co-owned by a Named Insured and covered under this insurance but only with respect to such co-owner's liability for bodily injury, property damage or personal and advertising injury as co-owner of such premises.
C. Lessor of Equipment
Any person or organization from whom a Named Insured leases equipment, but only with respect to liability for bodily injury, property damage or personal and advertising injury caused, in whole or in part, by the Named Insured's maintenance, operation or use of such equipment, provided that the occurrence giving rise to such bodily injury, property damage or the offense giving rise to such personal and advertising injury takes place prior to the termination of such lease.
D. Lessor of Land
Any person or organization from whom a Named Insured leases land but only with respect to liability for bodily injury, property damage or personal and advertising injury arising out of the ownership, maintenance or use of such land, provided that the occurrence giving rise to such bodily injury, property damage or the offense giving rise to such personal and advertising injury takes place prior to the termination of such lease. The coverage granted by this paragraph does not apply to structural alterations, new construction or demolition operations performed by, on behalf of, or for such additional insured.
E. Lessor of Premises
CNA74705XX (1-15) Policy No: 7017691303
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
An owner or lessor of premises leased to the Named Insured, or such owner or lessor's real estate (nerd and ported matine cirene ling tie to sue boil ngun or progen ana ringe oftense giving rise to such personal and advertising injury, takes place prior to the termination of such lease. The coverage granted by this paragraph does not apply to structural alterations, new construction or demolition operations performed by, on behalf of, or for such additional insured.
F. Mortgagee, Assignee or Receiver
A mortgagee, assignee or receiver of premises but only with respect to such mortgagee, assignee or receiver's liability for bodily injury, property damage or personal and advertising injury arising out of the Named Insured's ownership, maintenance, or use of a premises by a Named Insured.
The coverage granted by this paragraph does not apply to structural alterations, new construction or demolition operations performed by, on behalf of, or for such additional insured.
G. State or Governmental Agency or Subdivision or Political Subdivisions - Permits A state or governmental agency or subdivision or political subdivision that has issued a permit or authorization but only with respect to such state or governmental agency or subdivision or political subdivision's liability for bodily injury, property damage or personal and advertising injury arising out of:
1. the following hazards in connection with premises a Named Insured owns, rents, or controls and to which this insurance applies:
a. the existence, maintenance, repair, construction, erection, or removal of advertising signs, awnings, canopies, cellar entrances, coal holes, driveways, manholes, marquees, hoistaway openings, sidewalk vaults, street banners, or decorations and similar exposures; or b. the construction, erection, or removal of elevators; or c. the ownership, maintenance or use of any elevators covered by this insurance; or
2. the permitted or authorized operations performed by a Named Insured or on a Named Insured's The coverage granted by this paragraph does not apply to:
a. Bodily injury, property damage or personal and advertising injury arising out of operations performed for the state or governmental agency or subdivision or political subdivision; or b. Bodily injury or property damage included within the products-completed operations hazard.
With respect to this provision's requirement that additional insured status must be requested under a written contract or agreement, the Insurer will treat as a written contract any governmental permit that requires the Named Insured to add the governmental entity as an additional insured H. Trade Show Event Lessor
1. With respect to a Named Insured's participation in a trade show event as an exhibitor, presenter or displayer, any person or organization whom the Named Insured is required to include as an additional insured, but only with respect to such person or organization's liability for bodily injury, property damage or personal and advertising injury caused by:
a. the Named Insured's acts or omissions; or
b. the acts or omissions of those acting on the Named Insured's behalf, in the performance of the Named Insured's ongoing operations at the trade show event premises during the trade show event.
CNA74705XX (1-15) Policy No: 7017691303
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
2. The coverage granted by this paragraph does not apply to bodily injury or property damage included within the products-completed operations hazard.
2. ADDITIONAL INSURED - PRIMARY AND NON-CONTRIBUTORY TO ADDITIONAL INSURED'S INSURANCE The Other Insurance Condition in the COMMERCIAL GENERAL LIABILITY CONDITIONS Section is amended to add the following paragraph:
If the Named Insured has agreed in writing in a contract or agreement that this insurance is primary and non- contributory relative to an additional insured's own insurance, then this insurance is primary, and the Insurer will not seek contribution from that other insurance. For the purpose of this Provision 2., the additional insured's own surance means insurance on which the additional insured is a named insured. Otherwise, and notwithstandin nything to the contrary elsewhere in this Condition, the insurance provided to such person or organization excess of any other insurance available to such person or organization.
3. BODILY INJURY - EXPANDED DEFINITION
Under DEFINITIONS, the definition of bodily injury is deleted and replaced by the following:
Bodily injury means physical injury, sickness or disease sustained by a person, including death, humiliation, shock, mental anguish or mental injury sustained by that person at any time which results as a consequence of the physical injury, sickness or disease.
4. BROAD KNOWLEDGE OF OCCURRENCE/ NOTICE OF OCCURRENCE
Under CONDITIONS, the condition entitled Duties in The Event of Occurrence, Offense, Claim or Suit is amended to add the following provisions:
A. BROAD KNOWLEDGE OF OCCURRENCE
The Named Insured must give the Insurer or the Insurer's authorized representative notice of an occurrence, offense or claim only when the occurrence, offense or claim is known to a natural person Named Insured, to a partner, executive officer, manager or member of a Named Insured, or an employee designated by any of the above to give such notice.
B. NOTICE OF OCCURRENCE
The Named Insured's rights under this Coverage Part will not be prejudiced if the Named Insured fails to give the Insurer notice of an occurrence, offense or claim and that failure is solely due to the Named Insured's reasonable belief that the bodily injury or property damage is not covered under this Coverage Part. However, the Named Insured shall give written notice of such occurrence, offense or claim to the Insurer as soon as the Named Insured is aware that this insurance may apply to such occurrence, offense
5. BROAD NAMED INSURED
WHO IS AN INSURED is amended to delete its Paragraph 3. in its entirety and replace it with the following:
3. Pursuant to the limitations described in Paragraph 4. below, any organization in which a Named Insured has management control:
a. on the effective date of this Coverage Part; or
b. by reason of a Named Insured creating or acquiring the organization during the policy period, qualifies as a Named Insured, provided that there is no other similar liability insurance, whether primary, contributory, excess, contingent or otherwise, which provides coverage to such organization, or which would have provided coverage but for the exhaustion of its limit, and without regard to whether its coverage is broader or narrower than that provided by this insurance.
But this BROAD NAMED INSURED provision does not apply to:
(a) any partnership, limited liability company or joint venture; or CNA74705XX (1-15) Policy No: 7017691303
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
(b) any organization for which coverage is excluded by another endorsement attached to this Coverage For the purpose of this provision, management control means:
A. owning interests representing more than 50% of the voting, appointment or designation power for the selection of a majority of the Board of Directors of a corporation; or B. having the right, pursuant to a written trust agreement, to protect, control the use of, encumber or transfer or sell property held by a trust.
4. With respect to organizations which qualify as Named Insureds by virtue of Paragraph 3. above, this insurance does not apply to:
a. bodily injury or property damage that first occurred prior to the date of management control, or that first occurs after management control ceases; nor
b. personal or advertising injury caused by an offense that first occurred prior to the date of management control or that first occurs after management control ceases.
5. The insurance provided by this Coverage Part applies to Named Insureds when trading under their own names or under such other trading names or doing-business-as names (dba) as any Named Insured should choose to employ.
6. BROADENED LIABILITY COVERAGE FOR DAMAGE TO YOUR PRODUCT AND YOUR WORK A. Under COVERAGES, Coverage A - Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended to delete exclusions k. and I. and replace them with the following:
This insurance does not apply to:
k. Damage to Your Product
Property damage to your product arising out of it, or any part of it except when caused by or resulting from:
(1) fire;
(2) smoke;
(3) collapse; or
(4) explosion.
I. Damage to Your Work
Property damage to your work arising out of it, or any part of it and included in the products-completed operations hazard.
This exclusion does not apply:
(1) If the damaged work, or the work out of which the damage arises, was performed on the Named Insured's behalf by a subcontractor; or
(2) If the cause of loss to the damaged work arises as a result of:
(a) fire;
• (b) smoke;
(c) collapse; or
(d) explosion.
B. The following paragraph is added to LIMITS OF INSURANCE:
CNA74705XX (1-15) Policy No: 7017691303
Endorsement No:
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
Subject to 5. above, $100,000 is the most the Insurer will pay under Coverage A for the sum of damages arising out of any one occurrence because of property damage to your product and your work that is caused by fire, smoke, collapse or explosion and is included within the product-completed operations hazard. This sublimit does not apply to property damage to your work if the damaged work, or the work out of which the damage arises, was performed on the Named Insured's behalf by a subcontractor.
C. This Broadened Liability Coverage For Damage To Your Product And Your Work Provision does not apply if an endorsement of the same name is attached to this policy.
7. CONTRACTUAL LIABILITY - RAILROADS
With respect to operations performed within 50 feet of railroad property, the definition of insured contract is replaced by the following:
Insured Contract means:
a. A contract for a lease of premises. However, that portion of the contract for a lease of premises that indemnifies any person or organization for damage by fire to premises while rented to a Named Insured or temporarily occupied by a Named Insured with permission of the owner is not an insured contract; b. A sidetrack agreement;
c. Any easement or license agreement;
d. An obligation, as required by ordinance, to indemnify a municipality, except in connection with work for a municipality;
e. An elevator maintenance agreement;
f. That part of any other contract or agreement pertaining to the Named Insured's business (including an indemnification of a municipality in connection with work performed for a municipality) under which the Named Insured assumes the tort liability of another party to pay for bodily injury or property damage to a third person or organization. Tort liability means a liability that would be imposed by law in the absence of any contract or agreement.
Paragraph f. does not include that part of any contract or agreement:
(1) That indemnifies an architect, engineer or surveyor for injury or damage arising out of:
(a) Preparing, approving or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or (b) Giving directions or instructions, or failing to give them, if that is the primary cause of the injury or damage;
(2) Under which the Insured, if an architect, engineer or surveyor, assumes liability for an injury or damage arising out of the insured's rendering or failure to render professional services, including those listed in (1) above and supervisory, inspection, architectural or engineering activities.
8. ELECTRONIC DATA LIABILITY
A. Under COVERAGES, Coverage A - Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended to delete exclusion p. Electronic Data and replace it with the following:
This insurance does not apply to:
p. Access Or Disclosure Of Confidential Or Personal Information And Data-related Liability Damages arising out of:
(1) any access to or disclosure of any person's or organization's confidential or personal information, including patents, trade secrets, processing methods, customer lists, financial information, credit card information, health information or any other type of nonpublic information; or CNA74705XX 1-15) Policy No: 7017691303
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
(2) the loss of, loss of use of, damage to, corruption of, inability to access, or inability to manipulate electronic data that does not result from physical injury to tangible property.
However, unless Paragraph (1) above applies, this exclusion does not apply to damages because of bodily injury.
This exclusion applies even if damages are claimed for notification costs, credit monitoring expenses, forensic expenses, public relation expenses or any other loss, cost or expense incurred by the Named Insured or others arising out of that which is described in Paragraph (1) or (2) above.
B. The following paragraph is added to LIMITS OF INSURANCE:
Subject to 5. above, $100,000 is the most the Insurer will pay under Coverage A for all damages arising out of any one occurrence because of property damage that results from physical injury to tangible property and arises out of electronic data.
C. The following definition is added to DEFINITIONS:
Electronic data means information, facts or programs stored as or on, created or used on, or transmitted to or from computer software (including systems and applications software), hard or floppy disks, CD-ROMS, tapes, drives, cells, data processing devices or any other media which are used with electronically controlled equipment.
D. For the purpose of the coverage provided by this ELECTRONIC DATA LIABILITY Provision, the definition of property damage in DEFINITIONS is replaced by the following:
Property damage means:
a. Physical injury to tangible property, including all resulting loss of use of that property. All such loss of use shall be deemed to occur at the time of the physical injury that caused it; b. Loss of use of tangible property that is not physically injured. All such loss of use shall be deemed to occur at the time of the occurrence that caused it; or
c. Loss of, loss of use of, damage to, corruption of, inability to access, or inability to properly manipulate electronic data, resulting from physical injury to tangible property. All such loss of electronic data shall be deemed to occur at the time of the occurrence that caused it.
For the purposes of this insurance, electronic data is not tangible property.
E. If Electronic Data Liability is provided at a higher limit by another endorsement attached to this policy, then the $100,000 limit provided by this ELECTRONIC DATA LIABILITY Provision is part of, and not in addition to, that higher limit.
9. ESTATES, LEGAL REPRESENTATIVES, AND SPOUSES
The estates, heirs, legal representatives and spouses of any natural person Insured shall also be insured under this policy; provided, however, coverage is afforded to such estates, heirs, legal representatives, and spouses only for claims arising solely out of their capacity or status as such and, in the case of a spouse, where such claim seeks damages from marital community property, jointly held property or property transferred from such natural person Insured to such spouse. No coverage is provided for any act, error or omission of an estate, heir, legal representative, or spouse outside the scope of such person's capacity or status as such, provided however that the spouse of a natural person Named Insured and the spouses of members or partners of joint venture or partnership Named Insureds are Insureds with respect to such spouses' acts, errors or omissions in the conduct of the Named Insured's business.
10. EXPECTED OR INTENDED INJURY - EXCEPTION FOR REASONABLE FORCE Under COVERAGES, Coverage A - Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended to delete the exclusion entitled Expected or Intended Injury and replace it with the following:
CNA74705XX (1-15) Policy No: 7017691303
Endorsement No:
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
This insurance does not apply to:
Expected or Intended Injury
Bodily injury or property damage expected or intended from the standpoint of the Insured. This exclusion does not apply to bodily injury or property damage resulting from the use of reasonable force to protect persons or property.
11. GENERAL AGGREGATE LIMITS OF INSURANCE - PER PROJECT A. For each construction project away from premises the Named Insured owns or rents, a separate Construction Project General Aggregate Limit, equal to the amount of the General Aggregate Limit shown in the Declarations, is the most the Insurer will pay for the sum of:
1. All damages under Coverage A, except damages because of bodily injury or property damage included in the products-completed operations hazard; and
2. All medical expenses under Coverage C,
that arise from occurrences or accidents which can be attributed solely to ongoing operations at that construction project. Such payments shall not reduce the General Aggregate Limit shown in the Declarations, nor the Construction Project General Aggregate Limit of any other construction project.
B. All:
1. Damages under Coverage B, regardless of the number of locations or construction projects involved;
2. Damages under Coverage A, caused by occurrences which cannot be attributed solely to ongoing operations at a single construction project, except damages because of bodily injury or property damage included in the products-completed operations hazard; and
3. Medical expenses under Coverage C caused by accidents which cannot be attributed solely to ongoing operations at a single construction project,
will reduce the General Aggregate Limit shown in the Declarations.
C. The limits shown in the Declarations for Each Occurrence, for Damage To Premises Rented To You and for Medical Expense continue to apply, but will be subject to either the Construction Project General Aggregate Limit or the General Aggregate Limit shown in the Declarations, depending on whether the occurrence can be attributed solely to ongoing operations at a particular construction project.
D. When coverage for liability arising out of the products-completed operations hazard is provided, any payments for damages because of bodily injury or property damage included in the products- completed operations hazard will reduce the Products-Completed Operations Aggregate Limit shown in the Declarations, regardless of the number of projects involved.
E. If a single construction project away from premises owned by or rented to the Insured has been abandoned and then restarted, or if the authorized contracting parties deviate from plans, blueprints, designs, specifications or timetables, the project will still be deemed to be the same construction project.
F. The provisions of LIMITS OF INSURANCE not otherwise modified by this endorsement shall continue to apply as stipulated.
12. IN REM ACTIONS
A quasi in rem action against any vessel owned or operated by or for the Named Insured, or chartered by or for the Named Insured, will be treated in the same manner as though the action were in personam against the Named Insured.
13. INCIDENTAL HEALTH CARE MALPRACTICE COVERAGE
Solely with respect to bodily injury that arises out of a health care incident:
CNA74705XX (1-15) Policy No: 7017691303
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
A. Under COVERAGES, Coverage A - Bodily Injury and Property Damage Liability, the paragraph entitled Insuring Agreement is amended to replace Paragraphs 1.b. (1) and 1.b.(2) with the following:
b. This insurance applies to bodily injury provided that the professional health care services are incidental to the Named Insured's primary business purpose, and only if:
(1) such bodily injury is caused by an occurrence that takes place in the coverage territory. (2) the bodily injury first occurs during the policy period. All bodily injury arising from an occurrence will be deemed to have occurred at the time of the first act, error, or omission that is part of the occurrence; and
B. Under COVERAGES, Coverage A - Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended to:
i. add the following to the Employers Liability exclusion:
This exclusion applies only if the bodily injury arising from a health care incident is covered by other liability insurance available to the Insured (or which would have been available but for exhaustion of its ii. delete the exclusion entitled Contractual Liability and replace it with the following:
This insurance does not apply to:
Contractual Liability
the Insured's actual or alleged liability under any oral or written contract or agreement, including but not limited to express warranties or guarantees.
lili. add the following additional exclusions:
This insurance does not apply to:
Discrimination
any actual or alleged discrimination, humiliation or harassment, including but not limited to claims based on an individual's race, creed, color, age, gender, national origin, religion, disability, marital status or sexual orientation.
Dishonesty or Crime
Any actual or alleged dishonest, criminal or malicious act, error or omission.
Medicare/Medicaid Fraud
any actual or alleged violation of law with respect to Medicare, Medicaid, Tricare or any similar federal, state or local governmental program.
Services Excluded by Endorsement
Any health care incident for which coverage is excluded by endorsement.
C. DEFINITIONS is amended to:
i. add the following definitions:
Health care incident means an act, error or omission by the Named Insured's employees or volunteer workers in the rendering of:
a. professional health care services on behalf of the Named Insured or b. Good Samaritan services rendered in an emergency and for which no payment is demanded or received.
CNA74705XX (1-15) Policy No: 7017691303
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
Professional health care services means any health care services or the related furnishing of food, beverages, medical supplies or appliances by the following providers in their capacity as such but solely to the extent they are duly licensed as required:
a. Physician;
b. Nurse;
c. Nurse practitioner;
d. Emergency medical technician;
e. Paramedic;
f. Dentist;
g. Physical therapist;
h. Psychologist;
i. Speech therapist;
j. Other allied health professional; or
Professional health care services does not include any services rendered in connection with human clinical trials or product testing.
il. delete the definition of occurrence and replace it with the following:
Occurrence means a health care incident. All acts, errors or omissions that are logically connected by any common fact, circumstance, situation, transaction, event, advice or decision will be considered t constitute a single occurrence;
ill. amend the definition of Insured to:
a. add the following:
the Named Insured's employees are Insureds with respect to:
(1) bodily injury to a co-employee while in the course of the co-employee's employment by the Named Insured or while performing duties related to the conduct of the Named Insured's business; and
(2) bodily injury to a volunteer worker while performing duties related to the conduct of the Named Insured's business;
when such bodily injury arises out of a health care incident. the Named Insured's volunteer workers are Insureds with respect to:
(1) bodily injury to a co-volunteer worker while performing duties related to the conduct of the Named Insured's business; and
(2) bodily injury to an employee while in the course of the employee's employment by the Named Insured or while performing duties related to the conduct of the Named Insured's business;
when such bodily injury arises out of a health care incident. b. delete Subparagraphs (a), (b), (c) and (d) of Paragraph 2.a. (1) of WHO IS AN INSURED.
D. The Other Insurance condition is amended to delete Paragraph b. (1) in its entirety and replace it with the following:
Other Insurance
b. Excess Insurance
CNA74705XX (1-15) Policy No: 7017691303
Endorsement No:
Insured Name:
Copyright CNA All Rights Reserved.Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
(1) To the extent this insurance applies, it is excess over any other insurance, self insurance or risk transfer instrument, whether primary, excess, contingent or on any other basis, except tor insurance purchased specifically by the Named Insured to be excess of this coverage.
14. JOINT VENTURES / PARTNERSHIP / LIMITED LIABILITY COMPANIES WHO IS AN INSURED is amended to delete its last paragraph and replace it with the following:
No person or organization is an Insured with respect to the conduct of any current or past partnership, joint venture or limited liability company that is not shown as a Named Insured in the Declarations, except that if the Named Insured was a joint venturer, partner, or member of a limited liability company and such joint venture, partnership or limited liability company terminated prior to or during the policy period, such Named Insured is an Insured with respect to its interest in such joint venture, partnership or limited liability company but only to the extent that:
a. any oftense giving rise to personal and advertising injury occurred prior to such termination date, and the personal and advertising injury arising out of such offense first occurred after such termination date; b. the bodily injury or property damage first occurred after such termination date; and c. there is no other valid and collectible insurance purchased specifically to insure the partnership, joint venture or limited liability company; and
If the joint venture, partnership or limited liability company is or was insured under a consolidated (wrap-up) insurance program, then such insurance will always be considered valid and collectible for the purpose of paragraph c. above. But this provision will not serve to exclude bodily injury, property damage or personal and advertising injury that would otherwise be covered under the Contractors General Liability Extension Endorsement provision entitled WRAP-UP EXTENSION: OCIP, CCIP, OR CONSOLIDATED (WRAP-UP) INSURANCE PROGRAMS. Please see that provision for the definition of consolidated (wrap-up) insurance program.
15. LEGAL LIABILITY - DAMAGE TO PREMISES / ALIENATED PREMISES / PROPERTY IN THE NAMED
INSURED'S CARE, CUSTODY OR CONTROL
A. Under COVERAGES, Coverage A - Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended to delete exclusion j. Damage to Property in its entirety and replace it with the following:
This insurance does not apply to:
j. Damage to Property
Property damage to:
(1) Property the Named Insured owns, rents, or occupies, including any costs or expenses incurred by you, or any other person, organization or entity, for repair, replacement, enhancement, restoration or maintenance of such property for any reason, including prevention of injury to a person or damage to another's property;
(2) Premises the Named Insured sells, gives away or abandons, if the property damage arises out of any part of those premises;
(3) Property loaned to the Named Insured;
(4) Personal property in the care, custody or control of the Insured; (5) That particular part of real property on which the Named Insured or any contractors or subcontractors working directly or indirectly on the Named Insured's behalf are performing operations, if the property damage arises out of those operations; or (6) That particular part of any property that must be restored, repaired or replaced because your work was incorrectly performed on it.
CNA74705XX (1-15) Policy No: 7017691303
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
Paragraphs (1), (3) and (4) of this exclusion do not apply to property damage (other than damage by •ou as described in LIMiTs F INSURANCE.
Paragraph (2) of this exclusion does not apply if the premises are your work.
Paragraphs (3), (4), (5) and (6) of this exclusion do not apply to liability assumed under a sidetrack agreement.
Paragraph of this exclusion does not apply to property damage included in the products- completed operations hazard.
Paragraphs (3) and (4) of this exclusion do not apply to property damage to:
i. tools, or equipment the Named Insured borrows from others, nor ii. other personal property of others in the Named Insured's care, custody or control while being used in the Named Insured's operations away from any Named Insured's premises.
However, the coverage granted by this exception to Paragraphs (3) and (4) does not apply to:
a. property at a job site awaiting or during such property's installation, fabrication, or erection; b. property that is mobile equipment leased by an Insured; c. property that is an auto, aircraft or watercraft;
d. property in transit; or
any portion of property damage for which the Insured has available other valid and collectible insurance, or would have such insurance but for exhaustion of its limits, or but for application of one A separate limit of insurance and deductible apply to such property of others. See LIMITS OF INSURANCE as amended below.
B. Under COVERAGES, Coverage A - Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended to delete its last paragraph and replace it with the following:
Exclusions c. through n. do not apply to damage by fire to premises while rented to a Named Insured or temporarily occupied by a Named Insured with permission of the owner, nor to damage to the contents of premises rented to a Named Insured for a period of 7 or fewer consecutive days.
A separate limit of insurance applies to this coverage as described in LIMITS OF INSURANCE.
C. The following paragraph is added to LIMITS OF INSURANCE:
Subject to 5. above, $25,000 is the most the Insurer will pay under Coverage A for damages arising out of any one occurrence because of the sum of all property damage to borrowed tools or equipment, and to other personal property of others in the Named Insured's care, custody or control, while being used in the Named Insured's operations away from any Named Insured's premises. The Insurer's obligation to pay such property damage does not apply until the amount of such property damage exceeds $1,000. The Insurer has the right but not the duty to pay any portion of this $1,000 in order to effect settlement. If the Insurer exercises that right, the Named Insured will promptly reimburse the Insurer for any such amount.
O. Paragraph 6., Damage To Premises Rented To You Limit, of LIMITS OF INSURANCE is deleted and replaced by the following:
6. Subject to Paragraph 5. above, (the Each Occurrence Limit), the Damage To Premises Rented To You Limit is the most the Insurer will pay under Coverage A for damages because of property damage to any one premises while rented to the Named Insured or temporarily occupied by the Named Insured CNA74705XX (1-15) Policy No: 7017691303
Endorsement No:
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
with the permission of the owner, including contents of such premises rented to the Named Insured for a period of 7 or fewer consecutive days. The Damage To Premises Rented To You Limit is the greater of:
a. $500,000; or
b. The Damage To Premises Rented To You Limit shown in the Declarations.
E. Paragraph 4.b.(1)(a)(ii) of the Other Insurance Condition is deleted and replaced by the following:
(ii) That is property insurance for premises rented to the Named Insured, for premises temporarily occupied by the Named Insured with the permission of the owner; or for personal property of others in the Named Insured's care, custody or control;
16. LIQUOR LIABILITY
Under COVERAGES, Coverage A - Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended to delete the exclusion entitled Liquor Liability.
This LIQUOR LIABILITY provision does not apply to any person or organization who otherwise qualifies as an additional insured on this Coverage Part.
17. MEDICAL PAYMENTS
A. LIMITS OF INSURANCE is amended to delete Paragraph 7. (the Medical Expense Limit) and replace it with the following:
7. Subject to Paragraph 5. above (the Each Occurrence Limit), the Medical Expense Limit is the most the Insurer will pay under Coverage C - Medical Payments for all medical expenses because of bodily injury sustained by any one person. The Medical Expense Limit is the greater of:
(1) $15,000 unless a different amount is shown here: @@@@@@@@car@ce; or (2) the amount shown in the Declarations for Medical Expense Limit.
B. Under COVERAGES, the Insuring Agreement of Coverage C - Medical Payments is amended to replace Paragraph 1.a.(3)(b) with the following:
(b) The expenses are incurred and reported to the Insurer within three years of the date of the accident; and This Paragraph B. does not apply to medical expenses incurred in the state of Missouri.
18. NON-OWNED AIRCRAFT
Under COVERAGES, Coverage A - Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended as follows:
The exclusion entitled Aircraft, Auto or Watercraft is amended to add the following:
This exclusion does not apply to an aircraft not owned by any Named Insured, provided that:
1. the pilot in command holds a currently effective certificate issued by the duly constituted authority of the United States of America or Canada, designating that person as a commercial or airline transport pilot;
2. the aircraft is rented with a trained, paid crew to the Named Insured; and
3. the aircraft is not being used to carry persons or property for a charge.
19. NON-OWNED WATERCRAFT
Under COVERAGES, Coverage A - Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended to delete subparagraph (2) of the exclusion entitled Aircraft, Auto or Watercraft, and replace it with the following.
This exclusion does not apply to:
CNA74705XX (1-15) Policy No: 7017691303
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
(2) a watercraft that is not owned by any Named Insured, provided the watercraft is:
(a) less than 75 feet long; and
(b) not being used to carry persons or property for a charge.
20. PERSONAL AND ADVERTISING INJURY -DISCRIMINATION OR HUMILIATION A. Under DEFINITIONS, the definition of personal and advertising injury is amended to add the following tort:
• Discrimination or humiliation that results in injury to the feelings or reputation of a natural person.
B. Under COVERAGES, Coverage B - Personal and Advertising Injury Liability, the paragraph entitled Exclusions is amended to:
1. delete the Exclusion entitled Knowing Violation Of Rights Of Another and replace it with the following:
This insurance does not apply to:
Knowing Violation of Rights of Another
Personal and advertising injury caused by or at the direction of the insured with the knowledge that the act would violate the rights of another and would inflict personal and advertising injury. This exclusion shall not apply to discrimination or humiliation that results in injury to the feelings or reputation of a natural person, but only if such discrimination or humiliation is not done intentionally by or at the direction of:
(a) the Named Insured; or
(b) any executive officer, director, stockholder, partner, member or manager if the Named Insured is a limited liability company of the Named Insured
2. add the following exclusions:
This insurance does not apply to:
Employment Related Discrimination
Discrimination or humiliation directly or indirectly related to the employment, prospective employment, past employment or termination of employment of any person by any Insured.
Premises Related Discrimination
discrimination or humiliation arising out of the sale, rental, lease or sub-lease or prospective sale, rental, lease or sub-lease of any room, dwelling or premises by or at the direction of any Insured.
Notwithstanding the above, there is no coverage for fines or penalties levied or imposed by a governmental entity because of discrimination.
The coverage provided by this PERSONAL AND ADVERTISING INJURY -DISCRIMINATION OR HUMILIATION Provision does not apply to any person or organization whose status as an Insured derives solely from
• Provision 1. ADDITIONAL INSURED of this endorsement; or • attachment of an additional insured endorsement to this Coverage Part.
This PERSONAL AND ADVERTISING INJURY -DISCRIMINATION OR HUMILIATION Provision does not apply to any person or organization who otherwise qualifies as an additional insured on this Coverage Part.
21. PERSONAL AND ADVERTISING INJURY - CONTRACTUAL LIABILITY A. Under COVERAGES, Coverage B -Personal and Advertising Injury Liability, the paragraph entitled Exclusions is amended to delete the exclusion entitled Contractual Liability.
CNA74705XX (1-15) Policy No: 7017691303
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
B. Solely for the purpose of the coverage provided by this PERSONAL AND ADVERTISING INJURY - CONTRACTUAL LIABILITY provision, the following changes are made to the section entitled SUPPLEMENTARY PAYMENTS - COVERAGES A AND B:
1. Paragraph 2.d. is replaced by the following:
d. The allegations in the suit and the information the Insurer knows about the offense alleged in such suit are such that no conflict appears to exist between the interests of the Insured and the interests of the indemnitee;
2. The first unnumbered paragraph beneath Paragraph 2.f.(2)(b) is deleted and replaced by the following:
So long as the above conditions are met, attorneys fees incurred by the Insurer in the defense of that indemnitee, necessary litigation expenses incurred by the Insurer, and necessary litigation expenses incurred by the indemnitee at the Insurer's request will be paid as defense costs. Such payments will not be deemed to be damages for personal and advertising injury and will not reduce the limits of insurance.
C. This PERSONAL AND ADVERTISING INJURY - CONTRACTUAL LIABILITY Provision does not apply if Coverage B-Personal and Advertising Injury Liability is excluded by another endorsement attached to this Coverage Part.
This PERSONAL AND ADVERTISING INJURY - CONTRACTUAL LIABILITY Provision does not apply to any person or organization who otherwise qualifies as an additional insured on this Coverage Part.
22. PROPERTY DAMAGE - ELEVATORS
A. Under COVERAGES, Coverage A - Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended such that the Damage to Your Product Exclusion and subparagraphs (3), (4) and (6) of the Damage to Property Exclusion do not apply to property damage that results from the use of elevators.
B. Solely for the purpose of the coverage provided by this PROPERTY DAMAGE - ELEVATORS Provision, the Other Insurance conditions is amended to add the following paragraph:
This insurance is excess over any of the other insurance, whether primary, excess, contingent or on any other basis that is Property insurance covering property of others damaged from the use of elevators.
23. SUPPLEMENTARY PAYMENTS
The section entitled SUPPLEMENTARY PAYMENTS - COVERAGES A AND B is amended as follows:
A. Paragraph 1.b. is amended to delete the $250 limit shown for the cost of bail bonds and replace it with a $5,000. limit; and
B. Paragraph 1.d. is amended to delete the limit of $250 shown for daily loss of earnings and replace it with a $1,000. limit.
24. UNINTENTIONAL FAILURE TO DISCLOSE HAZARDS
If the Named Insured unintentionally fails to disclose all existing hazards at the inception date of the Named Insured's Coverage Part, the Insurer will not deny coverage under this Coverage Part because of such failure.
25. WAIVER OF SUBROGATION - BLANKET
Under CONDITIONS, the condition entitled Transfer Of Rights Of Recovery Against Others To Us is amended to add the following:
The Insurer waives any right of recovery the Insurer may have against any person or organization because of payments the Insurer makes for injury or damage arising out of:
1. the Named Insured's ongoing operations; or
2. your work included in the products-completed operations hazard.
CNA74705XX 1-15) Policy No: 7017691303
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
However, this waiver applies only when the Named Insured has agreed in writing to waive such rights of recovery in a written contract or written agreement, and only if such contract or agreement:
1. is in effect or becomes effective during the term of this Coverage Part; and
2. was executed prior to the bodily injury, property damage or personal and advertising injury giving rise to the claim.
26. WRAP-UP EXTENSION: OCIP, CCIP, OR CONSOLIDATED (WRAP-UP) INSURANCE PROGRAMS Note: The following provision does not apply to any public construction project in the state of Oklahoma, nor to any construction project in the state of Alaska, that is not permitted to be insured under a consolidated (wrap- up) insurance program by applicable state statute or regulation.
If the endorsement EXCLUSION - CONSTRUCTION WRAP-UP is attached to this policy, or another exclusionary endorsement pertaining to Owner Controlled Insurance Programs (O.C.I.P.) or Contractor Controlled Insurance Programs (C.C.I.P.) is attached, then the following changes apply:
A. The following wording is added to the above-referenced endorsement:
With respect to a consolidated (wrap-up) insurance program project in which the Named Insured is or was involved, this exclusion does not apply to those sums the Named Insured become legally obligated to pay as damages because of:
1. Bodily injury, property damage, or personal or advertising injury that occurs during the Named Insured's ongoing operations at the project, or during such operations of anyone acting on the Named Insured's behalf, nor
2. Bodily injury or property damage included within the products-completed operations hazard that arises out of those portions of the project that are not residential structures.
B. Condition 4. Other Insurance is amend to add the following subparagraph 4.b. (1)(c):
This insurance is excess over:
(c) Any of the other insurance whether primary, excess, contingent or any other basis that is insurance available to the Named Insured as a result of the Named Insured being a participant in a consolidated (wrap-up) insurance program, but only as respects the Named Insured's involvement in that consolidated (wrap-up) insurance program.
C. DEFINITIONS is amended to add the following definitions Consolidated (wrap-up) insurance program means a construction, erection or demolition project for which the prime contractor/project manager or owner of the construction project has secured general liability insurance covering some or all of the contractors or subcontractors involved in the project, such as an Owner Controlled Insurance Program (O.C.I.P.) or Contractor Controlled Insurance Program (C.C.I.P.).
Residential structure means any structure where 30% or more of the square foot area is used or is intended to be used for human residency, including but not limited to:
1. single or multifamily housing, apartments, condominiums, townhouses, co-operatives or planned unit developments; and
2. the common areas and structures appurtenant to the structures in paragraph 1. (including pools, hot tubs, detached garages, guest houses or any similar structures).
However, when there is no individual ownership of units, residential structure does not include military housing, college/university housing or dormitories, long term care facilities, hotels or motels. Residential structure also does not include hospitals or prisons.
This WRAP-UP EXTENSION: OCIP, CCIP, OR CONSOLIDATED (WRAP-UP) INSURANCE PROGRAMS Provision does not apply to any person or organization who otherwise qualifies as an additional insured on this Coverage Part.
CNA74705XX (1-15) Policy No: 7017691303
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission.
CNA
Contractors' General Liability Extension Endorsement
All other terms and conditions of the Policy remain unchanged.
This endorsement, which forms a part of and is for attachment to the Policy issued by the designated Insurers, takes effect on the effective date of said Policy at the hour stated in said Policy, unless another effective date is showr elow and expires concurrently with said Policy.
CNA74705XX (1-15) Policy No: 7017691303
Effective Date: 11/12/2021
Insured Name:
Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office, Inc., with its permission.
DATE (MM/DD/YYYY)
ACORD® CERTIFICATE OF LIABILITY INSURANCE
10/25/2022
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed.
If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsements).
CONTACT Automatic Data Processing Insurance Agency, Inc.
PRODUCER NAME:
PHONE 1-800-524-7024 (AC. No):
Automatic Data Processing Insurance Agency, Inc. (A/C No, Ext):
E-MAIL
ADDRESS:
1 Adp Boulevard INSURERS) AFFORDING COVERAGE NAIC #
Roseland NJ 07068 INSURER A: SIRIUS AMERICA INSURANCE COMPANY 38776 INSURED CJ Concrete Constructions Inc INSURER B:
INSURER C:
10142 Shoemaker Ave INSURER D:
INSURERE :
Santa Fe Spgs CA 90670 INSURER F:
COVERAGES CERTIFICATE NUMBER: 2688388 REVISION NUMBER:
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS ERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERM:
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS
INSR TADDL SUBRI POLICY EXP
TYPE OF INSURANCE POLICY NUMBER LIMITS
LTR INSO WVD.
COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE
DAMAGE TO RENTED
CLAIMS-MADE OCCUR PREMISES (Ea occurrence)
MED EXP (Any one person)
PERSONAL & ADV INJURY
GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $
PRO. LOC PRODUCTS - COMP/OP AGG
POLICY
OTHER: COMBINED SINGTE LIMIT
AUTOMOBILE LIABILITY Ea accident)
ANY AUTO BODILY INJURY (Per person)
OWNED SCHEDULED BODILY INJURY (Per accident) $
AUTOS ONLY AUTOS
HIRED NON-OWNED PROPERTY DAMAGE
AUTOS ONLY AUTOS ONLY Per accident)
UMBRELLA LIAB OCCUR EACH OCCURRENCE
EXCESS LIAB CLAIMS-MADE AGGREGATE $
DED RETENTIONS
WORKERS COMPENSATION XI STATUTE TOTH
ER
AND EMPLOYERS' LIABILITY Y/N
ANY PROPRIETOR/PARTNER/EXECUTIVE E.L. EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? N/A Y WC7398101 05/08/2022 05/08/2023 ELL DISEASE - EA EMPLOYEE $ 1,000,000
(Mandatory In NH)
E.L. DISEASE - POLICY LIMIT $1,000,000
DESCRIPTION OF OPERATIONS / LOCATIONS/ VEHICLES (ACORD 101, Additlonal Remarks Schedule, may be attached if more space is required) This certificate has a blanket Waiver of Subrogation for the following state(s) : CA
CERTIFICATE HOLDER CANCELLATION
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City of San Marino ACCORDANCE WITH THE POLICY PROVISIONS. 2200 Huntington Drive AUTHORIZED REPRESENTATIVE
San Marino CA 91108 1. Mui
© 1988-2015 ACORD CORPORATION. All rights reserved.
ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD