Quote No:
Date:
Quote Expires: 90 Days
Sales Contact:
Phone:
Email:
Project:
Item: Qty: Unit Price: Ext. Price:
13 15,993.00$ 47,979.00 $
23 8,910.00$ 26,730.00 $
74,709.00$
2 2,139.00$
1,867.73$
CA State Sales Tax 8.75% 6,537.04 $
85,252.76$
Pricing Notes:
Standard Terms and Conditions
These Terms and Conditions are attached to and incorporated by reference into the Proposal for products or services (“Proposal”) provided by Tolar Manufacturing Company, Inc. (“we”, “our” or “us”).
4. Freight cost is an ESTIMATE ONLY. Freight is invoiced at actual cost, without mark up, at time of shipment, unless specified above.
Print Name:
Date:
PO No:
6. Processing fee of 3% of total charge amount is additional and charged on all credit card payments.
5. Client provides unloading at destination, including forklift and labor as necessary.
1. In a case of discrepency between the unit price and the extension that unit price, the unit price shall govern.
2. If requested, structural engineering calculations from CA licensed engineer are provided at no additional cost.
3. Products are shipped knock down & unassembled in bulk packaging for unloading and installation by others. Hardware boxed by unit. Installation instructions are provided.
CalACT/MBTA Procurement Fee (2.5%)
Total:
APPROVED FOR PURCHASE:
Signature:
CalACT/MBTA FIRM Freight:
258 Mariah Circle
Corona, CA 92879
(951) 808-0081
www.tolarmfg.com
[email protected]
Customer:
Gamaliel Anguiano
Transit Manager
SMRT-City of Santa Maria Transit
110 S. Pine St., Suite 221
Santa Maria, CA 93458
MBTA/CALACT 21-
01 TRANSIT
SHELTERS 10/25
Pricing
Lead Time:
Sub-Total:
CalACT/MBTA Freight Zone
24156PMR
951-547-8209
2/12/2026
24 Weeks
[email protected]
From receipt of signed written order, and all
required approvals.
Terms: Terms subject to change. Final terms to be
determined based on credit history & bonding.
Net 30 Days From Invoice
Patrick Merrick
Description:
12' Signature Sunset Non-Advertising Transit Shelter 47778-00) featuring:
Signature series extrusion, aluminum roof panels secured with gasketed pressure ribs, perforated aluminum fascia , SMART branding plaque, four support post with multi-channel extrusion, spun escutcheon shoe covers, Tolar USC RMS80F (3390010 15902-XXX) UL listed dusk to dawn solar powered LED illumination under the shelter roof, 8' perforated metal bench, no back, three seat delineators, (12104-111), 20 gallon pole mount trash receptacle with hinged and covered lid (1578-01), durable baked powder coat finish color selected RAL 9007 Grey Aluminum, zinc anchors and all installation hardware - Base $ 15,765 Delete walls (-$1,087 )and replace with aluminum tube fascia ($ 330.00 and logo plate with logo $ 315.00 logo roof panels with clear poly overlay $ 335 x 2)- unpriced options-
USC/Axcentia 13" e-paper display (illuminated) pole mount (3920200), includes CMS access, mounting brackets, universal SIM CARD - repeat configuration from order 15349
Attachment E
Quote No:
Date:
Quote Expires: 90 Days
Sales Contact:
Phone:
Email:
Project:
Item: Qty: Unit Price: Ext. Price:
258 Mariah Circle
Corona, CA 92879
(951) 808-0081
www.tolarmfg.com
[email protected]
Customer:
Gamaliel Anguiano
Transit Manager
SMRT-City of Santa Maria Transit
110 S. Pine St., Suite 221
Santa Maria, CA 93458
MBTA/CALACT 21-
01 TRANSIT
SHELTERS 10/25
Pricing
Lead Time:
24156PMR
951-547-8209
2/12/2026
24 Weeks
[email protected]
From receipt of signed written order, and all
required approvals.
Terms: Terms subject to change. Final terms to be
determined based on credit history & bonding.
Net 30 Days From Invoice
Patrick Merrick
Description:
15. Amendment: No amendments to these Terms and Conditions can be made unless submitted in writing to us and signed and accepted by our President or his designee.
11. Returns: Due to the custom nature of our products, we cannot accept returns and we cannot permit cancellations once work has commenced.
12. Manufacturer’s Warranty: Our manufacturer’s warranty is set forth in a separate document.
13. Limitation of Liability: WE ARE NOT LIABLE TO BUYER OR ANY THIRD PARTY FOR ANY SPECIAL, INCIDENTAL, INDIRECT, CONSEQUENTIAL, PUNITIVE OR EXEMPLARY
DAMAGES OF ANY KIND ARISING FROM OR RELATING TO OUR OBLIGATIONS UNDER THE PROPOSAL, INCLUDING LOST PROFITS, LOSS OR USE, LOSS OF REVENUE OR COST OF CAPITAL. EXCEPT FOR PERSONAL INJURY OR DEATH DUE TO OUR MISCONDUCT, BUYER AGREES THAT THE TOTAL DAMAGES THAT CAN BE AWARDED
IN ANY CLAIM BY BUYER RELATING TO OUR OBLIGATIONS UNDER THE PROPOSAL (WHETHER BASED IN CONTRACT, TORT OR OTHERWISE, SHALL NOT EXCEED THE TOTAL PAID BY BUYER TO US UNDER THE PROPOSAL. BUYER AGREES THAT THE ABOVE LIMITATIONS ON LIABILITY PROVISIONS SHALL REMAIN IN FULL FORCE AND EFFECT EVEN IF IT IS FOUND THAT BUYER’S EXCLUSIVE REMEDY FAILS OF ITS ESSENTIAL PURPOSE.
14. Governing Law, Jurisdiction and Venue: The Proposal shall be governed by and construed in accordance with the laws of the State of California without reference to the choice of law principles thereof. Each party irrevocably submits to the jurisdiction of the Courts of the State of California and the United States District Court for the Central District of California.
9. Delayed Shipment: If buyer delays shipment, we may invoice for products when ready for shipment and, at our option, we may charge reasonable daily storage fees.
2. Vendor Status: Tolar Manufacturing Company, Inc. is a vendor supplier of manufactured products; is not a subcontractor or contractor; and is not subject to retainage or liquidated damages for any reason.
3. Payment Terms: Payment terms for services rendered or products manufactured by us shall be determined by us based on our determination of the credit worthiness of buyer and may require a deposit at time of order. Products are invoiced as shipped.
4. Late Payment Penalty: Buyer agrees to pay a charge equal to the lesser of (i) the highest rate allowable by law or (ii) 1.5% per month (18% per annum) on the unpaid balance with respect to any late payments. In addition, buyer will pay all our costs and expenses, including actual attorney’s fees, incurred in connection with enforcing the Proposal and/or collecting any past due payments. In the event buyer fails to make any payment when due, we have the right of setoff, the right to terminate the Proposal and/or to suspend further deliveries to buyer and the right to recover damages in addition to any other remedies available to us as a matter of law. Buyer has no right to setoff.
10. International Freight: We require the services of freight forwarder for all international shipments. Buyer may select the freight forwarder, subject to our approval. All fees, taxes and additional charges, in addition to the actual freight costs, are the responsibility of buyer.
5. Cancellation: If an order is cancelled by buyer after receipt of order authorization, and cancellation fee of 10% of order value may be assessed to the buyer, in addition to an the cost of materials purchased for the order, which may be invoiced to the buyer at time of cancellation.
1. Drawings and Specifications: All drawings and specifications submitted to our clients or potential clients are proprietary in nature and remain our property. They may be viewed, printed and distributed, without alteration, as reference for sales or for the process of specifying products for use. Detailed shop and erection drawings are provided to allow for field installation or repair. Sealed and stamped engineering calculations and drawings from an engineer licensed in the state of installation, if required, can be made available for an additional charge. Customers that provide their own drawing packages will retain ownership and be covered under a separate agreement.
6. Delivery, Title and Receipt: Unless otherwise provided in the proposal, all shelters are prefabricated and shipped knock-down and in bulk format (not packaged individually) for ease of handling and fast on-site installation. Neither buyer nor consignee shall have the right to direct or re-consign the goods to any other destination without our consent. All sales of products are F.O.B. our plant. Risk of loss of the products shall transfer to buyer upon delivery of the products to the common carrier.
7. Delivery Charges: Unless otherwise provided in the Proposal, buyer shall bear all the costs of transportation, including without limitation loading, unloading, storage, and freight charge. All delivery quotes allow for an approximate 2-hour unload window for a full truck. If this window is exceeded, additional charges may apply. All price quotes given for delivery are
based on estimates obtained at the time the quote was requested. Actual freight charges may vary.
8. Delivery Dates: Any delivery date(s) or period of delivery provided for in the Proposal is approximate and does not guarantee a particular date(s) or period of delivery. Estimated lead times are provided in the quote. Under no circumstances will we be liable for delay in delivery occasioned in whole or in part, by fire, flood, explosion, casualty, riot, strike, embargo, transportation delay, breakdown, accident, act of God or the public enemy, government authority, by our inability to secure materials, fuel, supply power or shipping space or any other circumstances beyond our reasonable control.
Attachment E