City Council and Concurrent Authorities
May 24, 2022

CONSTRUCTION CONTRACT
This contract is made and entered into on __________________, by and between SAK CONSTRUCTION, LLC, a STATE OF MISSOURI LIMITED LIABILITY COMPANY, with a business address at 864 HOFF ROAD, O’FALLON, MO 63366, hereinafter called "CONTRACTOR," and CITY OF STOCKTON, a municipal corporation, hereinafter called "CITY."
W I T N E S S E T H:

WHEREAS, plans and specifications for the construction of

SIERRA NEVADA STREET SANITARY SEWER REHABILITATION,
PROJECT NO. UW18029 (FORMERLY M18029), hereinafter called “PROJECT,” were regularly adopted by Council Resolution No. __________________, on _________________; and
WHEREAS, the contract for said work was regularly awarded to CONTRACTOR, by Council Resolution No. __________________, on ________________.

NOW, THEREFORE, in consideration of the promises and of the mutual covenants herein contained, the parties hereto expressly agree as follows:

CONTRACTOR
agrees:

1. SCOPE OF SERVICES. To do the work and furnish all the labor, materials, tools, equipment, and insurance required for the construction of PROJECT in accordance with the plans and specifications adopted on ____________________ , by Resolution No. __________________ . The "contract documents ," which include the bid documents, project plans , specifications, all letters of clarification, and the City of Stockton Standard Specifications and Plans, are incorporated into and made a part of this contract by this reference to the same extent as if fully set forth.

2. COMPENSATION. To do and perform the work contemplated hereby in a good and workmanlike manner and to furnish all labor, materials, tools , and equipment necessary therefore at the prices specified in
Exhibit A, attached hereto and by reference
made a part hereof, under the direction of and to the complete satisfaction of the Director of Public Works of the City of Stockton. Total compensation for services and reimbursement for costs shall not exceed $2,291,738, or as otherwise mutually agreed to in a Contract Change Order.

3. INSURANCE. CONTRACTOR shall not commence any work before obtaining, and shall maintain in force at all times during the duration and performance of this contract, the policies of insurance specified in
Exhibit B, which is attached to this
contract and incorporated by this reference, and as provided in the “contract documents” including Section 7- 1.06 of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016- 09-27, effective September 27, 2016.

It shall be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum i nsurance coverage requirements and/or limits shall be available to the Additional Insured.

Local Construction Contract - SAK CONSTRUCTION, LLC - PROJECT NO. UW18029 (Updated 12/31/20)

EXHIBIT 2

Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any insurance policy or proceeds available to the named Insured; whichever is greater.

The Additional Insured coverage under the CONTRACTOR’s policy shall be “primary and non-contributory” and will not seek contribution from the City of Stockton’s insurance or self-insurance and shall be at least as broad as ISO CG 20 01 04 13.

The limits of insurance requir ed in this agreement may be sati sfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contai n a provision that such co verage shall also apply on a primary and non-contributory basis for the benefit of the City of Stockton (if agreed to in a written contract or agreem ent) before the City of Stockton’s own insurance or self- insurance shall be called upon to protect it as a named insured.

All self-insured retentions (SIR) must be disclosed to the CITY’s Risk Management for approval and shall not reduce t he limits of liability. Payment Bond in the amount of the self-insured retention (SIR) may be required.

Policies containing any self-insured retention (SIR) provision shall provide or be endorsed to provide that the SIR may be satisfied by either the named insured or the CITY.

The CITY reserves the right to obtain a full certified copy of any insurance policy and endorsements.

Failure to exercise this right shall not constitute a waiver of right to exercise later.

CONTRACTOR shall maintain insurance as required by this contract to the fullest amount allowed by law and shall maintain insurance for a minimum of five years following the completion of this project. In the event cont ractor fails to obtain or maintain completed operations coverage as requir ed by this agreement, the City at its sole discretion may purchase the coverage required and the cost will be paid by contractor.

CONTRACTOR agrees to include with all Subcont ractors in their subcontract the same requirements and provisions of this agreement including the indemnity and insurance requirements to the extent they apply to the scope of the Subcontractor’s work.

Subcontractors hired by CONTRACTOR ag ree to be bound to CONTRACTOR and the CITY in the same manner and to the same extent as CONTRACTOR is bound to the CITY under the Contract Documents. Subcontractor further agrees to include these same provisions with any Sub-subcontractor. A copy of the CITY Contract Document Indemnity and Insurance provisions will be furnished to the Subcontractor upon request. The General CONTRACTOR shall require all sub-contractors to provide a valid certificate of insurance and the required endorsements in cluded in the agreement prior to commencement of any work and contractor will provide proof of compliance to the City.

4. INDEMNITY AND HOLD HARMLESS. With the exception that this section shall in no event be construed to require indemnification by Contractor to a greater extent than permitted under the public policy of the State of California, Contractor shall indemnify, protect, defend with counsel approved by City and at Contractor’s sole cost Local Construction Contract - SAK CONSTRUCTION, LLC - PROJECT NO. UW18029 (Updated 12/31/20)

EXHIBIT 2

and expense, and hold harmless City, its Mayo r, Council, official s, representatives, agents, employees, and volunteers from and against any and all claims, causes of action, liabilities, judgments, awar ds, losses, liens, claims, stop notices, damages, expenses, and costs (including without limitation attorne ys’ fees, expert and consultant fees, and other expenses of litigation) of every nature, including, but not limited to, death or injury to persons, or damage to prope rty, which arise out of or are in any way connected with the work performed, ma terials furnished, or services provided under this Agreement, or from any violation of any federal, State, or municipal law or ordinance, or City Policy, by Contractor or Contractor’s of ficers, agents, employees, volu nteers or subc ontractors.

Contractor shall not be obligated to indemnify or defend City for claims finally determined by a court of law or arbitrat or to arise from the active negligence or willful misconduct of the City. It is the intent of the Parties that this indemnity obligation is at least as broad as is permitted under California law. To the extent Califo rnia Civil Code sections 2782, et seq., limit the defense or indemnity obligations of Cont ractor to City, the intent hereunder is to provide the maximum defens e and indemnity obligations allowed by Contractor under the law. The indemnity set forth in this section shall not be limited by insurance requirements or by any other provision of this Agreement.

With exception that this section shall in no event be construed to require indemnification, including the duty to defend, by Contractor to a gr eater extent than permitted under the public policy of the State of California, the parties agree that Contractor’s duty to defend City is immediate and arises upon the filing of any clai m against the City for damages which arise out of or are in any way co nnected with the work performed, materials furnished, or services provided under this Ag reement by Contractor or Contractor’s officers, agents, employees, vo lunteers or subcontractors. Contractor’s duties and obligations to defend the City shall apply regardless of whethe r or not the issue of the City’s liability, breach of this Agreement, or other obligation or fault has been determined.

Contractor shall be immediat ely obligated to pay for City’s defense costs of the claim, including, but not limited to, court costs, attorney’s fees and costs, expert consultant and witness fees and costs, othe r witness fees, document repr oduction costs, arbitration fees, and, if after final judgm ent an appeal is pursued, all of such costs for the appeal.

At the conclusion of the claim, if there is any determinati on or finding of sole active negligence or willful misconduct on the part of the City, Cit y will then reimburse Contractor for amounts paid in excess of Contractor’s pr oportionate share of responsibility for the damages within 30 days after Contractor prov ides City with copies of all bills and expenses incurred in the defense of the claim(s). It is agreed between the parties that this reimbursemen t provision assures Contractor is not obligated to defend or indemnify City in an amount greater than provided for under California law, including, without limitation, California Civil Code secti
ons 2782, 2782.6, and 2782.8.

With the exception that this section sh all in no event be construed to require indemnification by Contractor to a greater extent than pe rmitted under the public policy of the State of California, and in addition to the other i ndemnity obligations in this Agreement, Contractor shall indemnify, de fend, and hold harmle ss City, its Mayor, Council, officials, representatives, agents , employees, and volunt eers from and against all claims, losses, expenses, and costs includi ng, but not limited to, attorneys’ fees, arising out of any claim br ought against the City by an employee, office, agent, or volunteer of Contractor, r egardless of whether such claim may be covered by any applicable workers compensation insurance. Contractor’s indemnification obligation is not limited in any way by any limitation on the amount or type of damages, compensation, Local Construction Contract - SAK CONSTRUCTION, LLC - PROJECT NO. UW18029 (Updated 12/31/20)

EXHIBIT 2

or benefits payable by or for the Contractor under workers’ compensation acts, disability acts, or other employee benefit acts.

The City’s acceptance of the insurance certificates required under this Agreement does not relieve the CONTRACTOR from its obligation under this paragraph. The indemnification obligations of this section shall survive the termination of this agreement.

Any exceptions to this language may result in a proposal being deemed non-responsive.

CONTRACTOR/Subcontractor's responsibil ity for such defense and indemnity obligations shall survive the termination or completion of this agreement for the full period of time allowed by law.

The defense and indemnification obligations of this agreement are undertaken in addition to, and shall not in any way be limited by, th e insurance obligations contained in this agreement. If any section, subsection, sentence, clause or phrase of this indemnification is for any reason held to be invalid or unconsti tutional, such decision shall not affect the validity of the remaining portions of this indemnification.

5. STANDARD PLANS A ND SPECIFICATIONS. The performance of said work and the furnishing of said materials shall be executed in ac cordance with Section 8-1.04B of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27-1213, effective September 27, 2016, and the provisions of the issued project specifications.

The Director of Public Works will furnish CONTRACTOR a weekly statement showing the number of days charged to the contract for the preceding week, the number of days specified for completion of the contract, and the number of days remaining to complete the contract. CONTRACTOR will be allowed one (1) week in which to file a written protest setting forth in what respects said weekly statement is incorrect, otherwise the statement shall be deemed to have been accepted by CONTRACTOR as correct.

6. WORKING DAYS. This work shall be diligently prosecuted to completion before the expiration of 120 WORKING DAYS beginning on the tenth calendar day after the date shown on the Notice to Proceed. It is agreed by the parties to the contract that in case all the work called for under the c ontract in all parts and requirements, is not finished or completed within the number of days as set fo rth, damage will be sustained by the CITY, and that it is and will be impracticable and extremely difficult to ascertain the actual damage which CITY will sustain in the event of and by reason of such delay; and it is therefore agreed that CONTRACTOR will pay to CITY the sum of FOUR THOUSAND FIVE HUNDRED AND NO/100 DOLLARS ($4,500.00) per day for each and every calendar days delay in finishing the work in excess of the number of days prescribed; and CONTRACTOR agrees to pay said liquidated damages as herein provided, and in case the same are not paid, agrees that CITY, may deduct the amount thereof from any monies due or that may become due CONTRACTOR under the contract.

It is further agreed that in case the work called for under the contract is not finished and completed in all parts and requirements within the number of days as specified, the CITY shall have the right to increase the number of days or not, as may seem best to serve the interest of CITY, and if the CITY decid es to increase the said number of days, the CITY shall further have the right to char ge to CONTRACTOR, CONTRACTOR's heirs, assigns or sureties, and to deduct from the final payment for the work, all or any part, as Local Construction Contract - SAK CONSTRUCTION, LLC - PROJECT NO. UW18029 (Updated 12/31/20)

EXHIBIT 2

may be deemed proper, the liquidated damages as specified or the actual cost of engineering, inspection, superintendence, and other ov erhead expenses which are directly chargeable to the contract, and which accrue during the period of such extension, whichever is greater, except the cost of fi nal surveys and preparation of final estimate shall not be included in such charges.

A working day shall not include, nor sha ll CONTRACTOR be assessed with liquidated damages nor the additional cost of engineeri ng and inspection during any delay beyond the time named for the completion of the work caused by acts of God or of the public enemy, acts of CITY, fire, fl oods, epidemics, quarantine restri ctions, strikes, and freight embargoes and subject to approval by the Direc tor of Public Works, inability to get materials ordered by CONTRACTOR or subcontractor due to such causes provided that CONTRACTOR shall notify the Director of Public Works in writing of the causes of delay within five (5) working days from the beginni ng of any such delay, and the Director shall ascertain the facts and the extent of the delay, and Director's findings of the facts thereon shall be final and conclusive.

If CONTRACTOR is delayed by reason of alterations made in these specifications, or by any act of the Director of Public Works or of the CITY, not contemplated by the contract, the time of completion shall be extended proportionately and CONTRACTOR shall be relieved during the period of such extens ion of any claim for liquidated damages, engineering or inspection charges or other penalties. CONTRACTOR shall have no claim for any other compensation for any such delay.

7. CONFORMANCE TO APPLICABLE LAWS. Contractor shall comply with all applicable Federal, State, and Municipal laws, rules and ordinances. Contractor shall not discriminate in the employme nt of persons or in the prov ision of services under this Contract on the basis of any legally protected classification, including race, color, national origin, ancestry, sex or religion of such person.
a. TITLE VI
Title VI of the Civil Rights Act of 1964 requires that “no person in the United States shall, on the grounds of race, color, or national origin, be excluded from participation in, be denied the benefits o f, or be subjected to discrimination under any pr ogram or activity receiving federal financial assistance.” (42 USC Section 2000d)
http://www.dol.gov/oas
am/regs/statutes/titlevi.htm.

The City of Stockton requires compliance with the requirements of Title VI in all of its programs and activities regardless of funding source. b. DISCRIMINATION AND HARA

SSMENT POLICY
The City of Stockton has a Discriminat ion and Harassment Policy (Exhibit C). The purpose of this policy is to reaffirm
the CITY’s commitment to
demonstrating respect for all individuals by strictly prohibiting discrimination and harassment, including sexual harassment in the workplace, to define the types of behavior and conduct prohibited by this policy, and to set forth Local Construction Contract - SAK CONSTRUCTION, LLC - PROJECT NO. UW18029 (Updated 12/31/20)

EXHIBIT 2
a procedure for reporting, investigat ing, and resolving complaints of discrimination and harassment in the workplace.
c. LABOR STANDARDS PROVISIO NS/CALIFORNIA LABOR CODE
The bidder shall understand that conditions set forth in Chapter 1, Part 7, Division 2 of the Calif ornia Labor Code shall be considered part of the contract agreement.
https://leginfo.legislature.ca.gov/faces/codes_displayText.xhtml?lawCode= LAB&division=2.&title=&part=7.&chapter=1.&article=2.
d. PREVAILING WAGE
CONTRACTOR and any subcontractor shall pay each employee engaged in the trade or occupation not less than the prevailing hourly wage rate. In accordance with the provis ions of Section 1770 of the Labor Code, the Director of Department of Industrial Relations of the State of California ha s
determined the general prevailing rates of wages and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for in Section 1773. 1, apprenticeship or other training programs authorized by Section 3093 and similar purposes applicable to the work to be done. CONTRACTOR performing the work under this contract shall obtain a copy of t he wage rate determination and shall distribute copies to each subcontract or. As the wage determination for each craft reflects an expiration date, it shall be the prime CONTRACTOR and each subcontractor's responsibility to ensure that the prevailing wage rates of concern is current and paid to the employee.
i. The CONTRACTOR performing the work shall be responsible for obtaining a copy of the State wage rate determination. State wage rates may be obtained at
http://www.dir.ca.gov/OPRL/pwd/Determinations/Northern/Northern.p df. The CONTRACTOR shall be responsible for posting said wage rates at a prominent location at the work site and shall maintain same in a good readable condition for the duration of the work. ii. Should the CONTRACTOR choose to work on a Saturday, Sunday or on a holiday recognized by the Labor Unions, the CONTRACTOR shall reimburse the CITY the actual co st of engineering, inspection, superintendence, and or other overhead expenses which are directly chargeable to the contract. Should such work be undertaken at the request of the CITY, reimbursement will not be required. To conform strictly with the provisions of Division 2, Part 7, Chapter 1, Article 2, of the Labor Code of the State of Califo rnia. To forfeit as a penalty to CITY the sum of TWENTY-FIVE AND NO/100 DOLLARS ($25.00) for each laborer, worker, or mechanic employed by CONTRACTOR, or by any subcontractor under CONTRACTOR, in the execution of this contract, for each calendar day during which any laborer, worker, or mechanic is required or permitted to work more than eight (8) hours and who is not paid the general prevailing rate of per diem wages for Local Construction Contract - SAK CONSTRUCTION, LLC - PROJECT NO. UW18029 (Updated 12/31/20)

EXHIBIT 2
holiday and overtime work in violat ion of the provisions of Sections 1770 to 1781 of the Labor Code of the State of California. That all sums forfeited under the provisions of the foregoing sections shall be deducted from the payments to be ma de under the terms of this contract.
iii. The CONTRACTOR to whom the cont ract is awarded shall ensure that the prime and each subcontractor will in accordance with Section 1776 of the Labor Code, maintain certified payroll records. A copy of said records shall be provided with each invoice to the Public Works Department, Attention Contract Co mpliance Officer. It shall be the CONTRACTOR’S responsibility to obtain copies of the current prevailing wage rate determination for all subcontractors. Additionally, certified payroll records must be uploaded to the DIR website as required by labor code.
iv. The CONTRACTOR shall comply wit h the provisions established in Section 1777.5 of the Labor Code concerning the 1) certified approval by local joint apprenticeship committees for the employment and training of apprentices, and 2) contri bution of funds to administer and conduct apprenticeship programs, if applicable to the job. e. LOCAL EMPLOYMENT ORDINANCE
Pursuant to Stockton Municipal Code Section 3.68.095 the CONTRACTOR and all subcontractors shall make a good fa ith effort to employ at least 50 percent of the workforce on this proj ect from local residents, as measured by total labor work hours. Failure of any CONTRACT
OR or subcontractor
to comply with these requirements shall be deemed a material breach of the contract or subcontract. CONT RACTORS and subcontractors shall maintain records necessary for moni toring their compliance with section

3.68.095.
f. COMMUNITY WORKFORCE TRAINING AGREEMENT
Pursuant to the implementation of the Community Workforce Training Agreement (CWTA) adopted by the Cit y Council on July 26, 2016, the successful bidder shall be required to comply with the provisions of CWTA. For any project subject to this Agreement, the Local Hire, Priority Apprentice and Workforce Development Program requirements shall apply in lieu of the requirements of Stockton Municipal Code Section 3.68.095 and no separate compliance with Secti on 3.68.095 will be r equired of the Contractors/Employers working on the project (EXHIBIT D).

CITY agrees:

8. COMPENSATION. To pay CONTRACTOR for the work herein
contemplated in the following manner: Progress payments will be made on or about the first day of each calendar month, in such sum as shall make the aggregate of payment up to such day equal to ninety-five percent (95%) of the proportional contract price, upon Local Construction Contract - SAK CONSTRUCTION, LLC - PROJECT NO. UW18029 (Updated 12/31/20)

EXHIBIT 2

the basis of the progress certif icate of the Director of Public Works as to the amount of work done and the proportional amount of the contract price represented therefore; and all of the remaining part of t he contract price not as aforesai d paid, shall be paid at the expiration of thirty-five (35) days from the completion of said work of construction and the certification by the Director of Public Works of such completion.

9. SECURITIES. Pursuant to Section 22300 of the Public Contract Code, CONTRACTOR will be permitted, at its request and sole expense, to substitute securities for any monies withheld by the CITY to ensure performance under the contract. Said securities will be deposited either with the CITY or with a State or federally chartered bank as escrow agent. Securities eligible for this substitution are those listed in Section 16430 of the California Government Code or bank or savings and loan certificates of deposit.

CONTRACTOR shall be the beneficial owner of any securities substituted for monies withheld and shall receive any interest thereon.

10. CHANGE ORDERS. CITY reserves the right to make such alterations, deviations, additions to or omissions from the plans and specifications, including the right to increase or decrease the quantity of any item or portion of the work, as may be deemed by the Engineer to be necessary or advisable and to require su ch extra work as may be determined by the Engineer to be required for the proper completion or construction of the whole work contemplated.

Any such changes will be set forth in a contract change order which will specify, in addition to the work done in connection with the change made, adjustment of contract time, if any, and the basis of compensation for such work . A contract change order will not become effective until approved by the City Manager and/or the City Council.

Processing of change orders shall be in accordance with Section 4-1. 05A of the City of Stockton Standard Specifications and Plans as adopted by Council on September 27, 2016, by Resolution No. 2016-09-27-1213, effective September 27, 2016, or as otherwise amended by Council. When the compensation for an item of work is subject to adjustment under the provisions of Standard Spec ifications and Plans, Section 4-1.05A, CONTRACTOR shall, upon request, promptly furnish the Engineer with adequate detailed cost data for such item of work.

11. AUDITS. CITY reserves the right to peri odically audit all charges made by CONTRACTOR to CITY for services under the contract. Upon request, CONTRACTOR agrees to furnish CITY, or a designated repr esentative, with necessary information and assistance.

CONTRACTOR agrees that CITY or its delegate will have the right to review, obtain and copy all records pertaining to performance of the contract. CONTRACTOR agrees to provide CITY or its delegate with any rele vant information requested and shall permit CITY or its delegate access to its prem ises, upon reasonable not ice, during normal business hours for the purpose of interviewing employees and inspecting and copying such books, records, accounts, and other material that may be relevant to a matter under investigation for the purpos e of determining compliance with this requirement.

CONTRACTOR further agrees to maintain such records for a period of three (3) years after final payment under the contract.

Local Construction Contract - SAK CONSTRUCTION, LLC - PROJECT NO. UW18029 (Updated 12/31/20)

EXHIBIT 2

12. WAIVER. It is expressly understood and agreed by and between the parties hereto that a waiver of any of the conditions of this contract shall not be considered a waiver of any of the other conditions thereof.

It is further understood and agreed by and between the parties hereto that time is of the essence of this contract in
all respects.

IN WITNESS WHEREOF, the parties hereto have hereunto affixed their hands and seals the day and year first above written.

ATTEST:

ELIZA R. GARZA, CMC

CITY CLERK
By: __________ _
APPROVED AS TO FORM & CONTENT:

LORI M. ASUNCION

OFFICE OF THE CITY ATTORNEY
By:-------------

DEPUTY CITY ATTORNEY
CITY:

By: ____________ _

HARRY BLACK

CITY MANAGER
Tax Identification No.

Local Construction Contract - SAK CONSTRUCTION, LLC - PROJECT NO. UW18029 (Updated 12/31/20)

EXHIBIT 2
Letter of Clarification No. 2
Sierra Nevada Sanitary Sewer Rehabilitation, Project No. UW18029 January 31, 2022

SIERRA NEVADA STREET SANITARY SEWER REHABILITATION
PROJECT NO. UW18029 (FORMERLY PROJECT NO. M18029)

BIDDI NG SC HEDULE
Each bidder shall bid each item, including all alternate bid(s). Failure to bid an item shall be just cause for considering the bid as non-responsive. Line-item costs should include all Contractor's overhead and profit and indirect costs. Bids not presented on City forms shall be cause for considering the bid as non-responsive.

BASE PROJECT BID ITEMS
Item Description Unit Quantity Unit price Total Price
1 Mobilization and Demobilization LS 1 300,000.00 300,000.00 2 Sheeting, Shoring, & Bracing LS 1 100,000.00 100,000.00 3 Cured-in-place-Pipe Rehabilitation of 36" LF 1,101
Concrete Sewer - Sierra Nevada Street 412.00 453,612.00 4 Cured-in-Place-Pipe Rehabilitation of 36" LF 441
Concrete Sewer with Preliner -Hazelton 486.00 214,326.00 5 Rehabilitation of Maintenance Hole - LS 1
Sierra Nevada & Hazelton 16,300.00 16,300.00
6 Removal and Replacement of Existing LS 1
Type 2 Maintenance Hole with Stubout -
Sierra Nevada & Worth 155,900.00 155,900.00
7 Rehabilitation of Maintenance Hole - near LS 1
BNSF Railroad 24,700.00 24,700.00
8 Installation of New Type 2 Maintenance EA 1
Hole with Internal Drop 89,600.00 89,600.00
9 Installation of New Type 2 Maintenance EA 1 86,400.00 86,400.00 10 Clean and CCTV of Sanitary Sewer Lines LS 1 29,700.00 29,700.00 11 Upstream Plug Installation LS 1 20,000.00 20,000.00
12 Downstream Bypass Pumping LS 1 73,700.00 73,700.00
13 Scotts Ave Reroute LS 1 77,900.00 77,900.00
14 Traffic Staging System LS 1 114,200.00 114,200.00
15 Pavement Restoration LS 1 47,400.00 47,400.00
16 Stormwater Handling and
Erosion Control LS 1 10,000.00 10,000.00
17 Site Restoration LS 1 21,100.00 21,100.00
BASE PROJECT BID ITEMS TOTAL 1,834,838.00

EXHIBIT A

EXHIBIT 2
Letter of Clarification No. 2
Sierra Nevada Sanitary Sewer Rehabilitation, Project No. UW18029 January 31, 2022

ALTERNATIVE BID ITEMS
Item
SA
7A
18A
Description Unit Quantity
Removal and Replacement of existing LS 1
Type 2 Maintenance Hole - Sierra Nevada
& Hazelton
Removal and Replacement of Existing LS 1
Type 2 Maintenance Hole - near BNSF
Railroad
Point Repair of Deteriorated Sewer LS 1
Pipeline in Advance of CIPP

ALTERNATIVE BID ITEMS TOT AL

BASE PROJECT BID ITEMS SUBTOTAL
(BASIS FOR CONTRACT AWARD)

ALTERNATIVE BID ITEMS SUBTOTAL

TOTAL BID
(BASE PROJECT BID ITEMS PLUS ALTERNATIVE BID ITEMS)

BIDDER'S NAME
SAK Construction, LLC
Unit price Total Price
61,100.00 61,100.00
359,000.00 359,000.00
36,800.00 36,800.00
456,900.00
1 ,834,838.00
456,900.00
2,291,738.00

EXHIBIT A

EXHIBIT 2
The City of Stockton is now using www.PINSAdvantage.com to track Insurance Certificates and all related documents.

The PINS system starts with The City of Stockton. A Stockton User logs into PINS and emails a request for proof of insurance to the Vendor/Contractor. The Vendor/Contractor forwards the request email to their Insurance Agent(s). The Insurance Agent(s) logs into www.PINSAdvantage.com and completes the insurance certificate online.
www.pinsadvantage.com
+ 1 626 844 1838
WHAT IS THE PROCESS?
Note: Vendors will receive the insurance request email from: [email protected] Thank you for your compliance!
01 02
03 04
The Vendor/
Contractor forwards
the email to their
insurance agent(s).

PINS notifies
The City of Stockton
that documents have
been submitted and
automatically checks
for compliance.

Agent(s) log into
PINSAdvantage.com
and complete
the insurance
certificate online
A Stockton User
logs into PINS and
emails a request for
insurance to the
Vendor/Contractor

EXHIBIT B

EXHIBIT 2
REV 2017_09_01
NOTE: The City of Stockton is now using the online insurance program PINS Advantage. Once you have been awarded a contract you will receive an email from the City’s online insurance program requesting you to forward the email to your insurance provider(s). Please see attached flyer regarding PINS Advantage.

Sierra Nevada Street Sanitary Sewer Rehabilitation
Project No. UW18029 (formerly M18029)
Insurance Requirements for Construction Contracts
Contractor shall procure and maintain for the duration of the contract, and for five (5) years thereafter, insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, their agents, representatives, employees, or subcontractors. In the event contractor fails to obtain or maintain completed operations coverage as required by this agreement, the City, at its sole discretion, may purchase the coverage required and the cost will be paid by the contractor.

MINIMUM SCOPE AND LIMIT OF INSURANCE
Coverage shall be at least as broad as:

1. Commercial General Liability (CGL): Insurance Services Office (ISO) Form CG 00 01 covering CGL on an “occurrence” basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $5,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit.

2. Automobile Liability: Insurance Services Office Form CA 0001 covering Code 1 (any auto), with limits no less than $5,000,000 per accident for bodily injury and property damage.

3. Workers’ Compensation insurance as required by the State of California, with Statutory Limits, and Employers’ Liability insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.

4. Builder’s Risk (Course of Construction) insurance utilizing an “All Risk” (Special Perils) coverage form, with limits equal to the completed value of the project and no coinsurance penalty provisions.

5. Surety Bonds as described below.

6. Professional Liability (Errors and Omissions) Insurance appropriate to the Contractor’s profession, with limit no less than $2,000,000 per occurrence or claim, $2,000,000 aggregate. (If Claims-made, see below.

EXHIBIT B

EXHIBIT 2
REV 2017_09_01
Contractors’ Pollution Legal Liability and/or Asbestos Legal Liability with limits no less than $2,000,000 per occurrence or claim, and $2,000,000 policy aggregate.

It shall be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be available to the Additional Insured. Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any Insurance policy or proceeds available to the named insured; whichever is greater. No representation is made that the minimum insurance requirements of this agreement are sufficient to cover the obligations of the Contractor under this agreement.

Limits of Insurance
The limits of insurance required in this agreement may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis before the City’s own insurance or self-insurance shall be called upon to protect it as a named insured.

Other Insurance Provisions
The insurance policies are to contain, or be endorsed to contain, the follo wing
provisions:

Additional Insured Status
The City of Stockton, its officers, officials, employees, and volunteers are to be covered as additional insureds on the CGL policy with respect to liability arising out of work or operations performed by or on be
half of the Contractor including materials, parts, or
equipment furnished in connection with such work or operations. General liability coverage can be provided in the form of an endorsement to the Contractor’s insurance (at least as broad as ISO Form CG 20 10 11 85 or if not available, through the addition of both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 if a later edition is used). Additional insured Name of Organization shall read “City of Stockton, its officers, officials, employees, and volunteers.” Policy shall cover City of Stockton, its officers, officials, employees, and volunteers for all locations work is done under this contract.

Primary Coverage
The Additional Insured coverage under the Contractor’s policy shall be “primary and non-contributory” and will not seek contribution from
the City’s insurance or self-
insurance and shall be at least as broad as CG 20 01 04 13. The City of Stockton does

EXHIBIT B

EXHIBIT 2
REV 2017_09_01
not accept endorsements limiting the Contractor’s insurance coverage to the sole negligence of the Named Insured.

Builder’s Risk (Course of Construction) Insurance
Contractor may submit evidence of Builder’s Risk insurance in the form o f Course of
Construction coverage. Such coverage shall name the City of Stockton as a loss payee as their interest may appear.

If the project does not involve new or major reconstruction, at the option of the City of Stockton, an Installation Floater may be acceptable. For such projects, a Property Installation Floater shall be obtained that provides for the improvement, remodel, modification, alteration, conversion or adjustment to existing buildings, structures, processes, machinery and equipment. The Property Installation Floater shall provide property damage coverage for any building, structure, machinery or equipment damaged, impaired, broken, or destroyed during the performance of the Work, including during transit, installation, and testing at the City of Stockton’s site.

Claims Made Policies – (Note – applicable only to professional and/or pollution liability)
If any coverage required is written on a claims-made coverage form:

1. The retroactive date must
be shown, and this date must be before the execution
date of the contract or the beginning of contract work.

2. Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of contract work.

3. If coverage is canceled or non-renewed, and not replaced with another claims-made policy form with a retroactive date prior to the contract effective, or start of work date, the Contractor must purchase extended reporting period coverage for a minimum of five (5) years after completion of contract work.

4. A copy of the claims reporting requirements must be submitted to the City of Stockton for review.

5. If the services involve lead-based paint or asbestos identification/remediation, the Contractors Pollution Liability policy shall not contain lead-based paint or asbestos exclusions. If the services involve mold identification/remediation, the Contractors Pollution Liability policy shall not contain a mold exclusion, and the definition of Pollution shall include microbial matter, including mold.

EXHIBIT B

EXHIBIT 2
REV 2017_09_01
Notice of Cancellation
Each insurance policy required above shall provide that coverage sh all not be canceled,
except with notice to the City of Stockton.

Waiver of Subrogation
Contractor hereby grants to City of Stockton a waiver of any right to subrogation which any insurer of
said Contractor may acquire against the City of Stockton by virtue of the payment of any loss under such insurance. Contractor agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation, but this provision applies regardless of whether or not the City of Stockton has received a waiver of subrogation endorsement from the insurer. The Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of the City of Stockton for all work performed by the Contractor, its employees, agents and subcontractors.

Self-Insured Retentions
All Self-insured retentions must be discl
osed to Risk Management for approval and shall
not reduce the limits of liability. The City of Stockton may require the Contractor to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention.

The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the named insured or City of Stockton.

Acceptability of Insurers
Insurance is to be placed with insurers with a current A.M. Best’s rating of no less than A:VII, unless otherwise acceptable to the City of Stockton.

Verification of Coverage
Contractor shall furnish the City of Stockton with original certificates and amendatory endorsements or copies of the a
pplicable policy language effecting coverage required
by this clause. All certificates and endorsements are to be received and approved by the City of Stockton Risk Services before work commences. However, failure to obtain the required documents prior to the work beginning shall not waive the Contractor’s obligation to provide them. The City of Stockton reserves the right to require complete, certified copies of all required insurance policies, including endorsements required by these specifications, at any time.

EXHIBIT B

EXHIBIT 2
REV 2017_09_01
Contractor shall, prior to the commencement of work under this Agreement, provide the City of Stockton with a copy of its declarations page(s) and endorsement page(s) for each of the required policies.

Subcontractors
Contractors shall require and verify that all subcontractors, or other parties hired for this work, purchase and mainta
in coverage for indemnity and insurance requirements
as least as broad as specified in this agreement to the extent they apply to the scope of the subcontractor’s work with the same certificate of insurance requirements and naming as additional insureds all parties to this contract. Contractor shall include the following language in their agreement with Subcontractors: Subcontractors hired by Contractor agree to be bound to Contractor and City in the same manner and to the same extent as Contractor is bound to City under the contract documents and provide a valid certificate of insurance and the required endorsements included in the agreement as proof of compliance prior to commencement of any work and to include this same requirement for any subcontractors they hire for this work. A copy of the owner contract document indemnity and insurance provisions will be furnished to the subcontractor upon request. Contractor shall provide proof of such compliance and verification to the City upon request.

Surety Bonds
Contractor shall provide the following Surety Bonds:

1. Bid bond

2. Performance bond

3. Payment bond (or Labor and M
aterial bond)

4. Maintenance bond
The Payment Bond and the Performance Bond shall be in a sum equal to one hundred percent (100%) of the contract price. If the Performance Bond provides for a one-year warranty a separate Maintenance Bond is not necessary. If the warranty period specified in the contract is for longer than one year a Maintenance Bond equal to 10% of the contract price is required. Bonds shall be duly executed by a responsible corporate surety, authorized to issue such bonds in the State of California and secured through an authorized agent with an office in California.

EXHIBIT B

EXHIBIT 2
REV 2017_09_01
Special Risks or Circumstances
City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances.

Certificate Holder Address
Proper address for mailing certificates, endorsements and notices shall be:

City of Stockton
Attn: City Risk Services
400 E Main Street, 3rd Floor – HR
Stockton, CA 95202

EXHIBIT B

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 1 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 I. PURPOSE
The purpose of this policy is to reaffirm the City's commitment to demonstrating respect for all individuals by strictly prohibiting discrimination and harassment, including sexual harassment in the workplace. This policy defines prohibited behavior and conduct, and sets forth a procedure for reporting, investigating and resolving complaints of discrimination, harassment, in the workplace, including retaliation and hostile work environment.

II. POLICY
A. The City of Stockton prohibits any form of discrimination and/or harassment of any person based on race, religious creed, color, national origin, ancestry, military and veterans status, physical or mental disability, medical condition, genetic characteristics or information, denial of family and medical care leave, marital
status, sexual orientation, sex (including gender, gender identity, gender expression, transgender, pregnancy, childbirth and breastfeeding), political affiliation, age (40 and older), concerted labor activity, or any other category or attribute consistent with state or federal law.

All such discrimination and harassment is unlawful and shall not be tolerated. In addition, under the federal Affordable Care Act (ACA), the City of Stockton prohibits discrimination and/or harassment, or retaliation against an employee who obtains coverage, receives a tax credit or subsidy through the Health Care "Market Place" or "Exchange."
B. It is an unlawful employment practice to discriminate against or to harass an unpaid intern or volunteer on the basis of any legally protected classification unless an exception applies, such as a bona fide occupational qualification.

C. The City will neither tolerate nor condone discrimination and/or harassment of employees by managers, supervisors, co-workers, or non-employees with whom City employees have a business service, or professional relationship.

D. All City employees and non-employees share a responsibility to assist in

EXHIBIT C

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 2 of 14
DISCRIMINATION AND Effective Date: Revised From: HARASSMENT POLICY 7/27/09 5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 maintaining an employment environment free of discrimination and harassment. This policy applies to all aspects of City employment, including, but not limited to, hiring, reassignment, placement, promotion, employment action, disciplinary action, layoff, reemployment, transfer, leave of absence, compensation and benefits, training; or other terms of treatment of that person in an unpaid internship, or another limited duration program to provide unpaid work experience for that person, or the harassment of an unpaid intern or volunteer.

E. All allegations of discrimination and/or harassment shall be investigated immediately by the City, in accordance with this policy. If it is determined that any prohibited activity has occurred, remedial action shall be taken. Such action may include discipline up to and including discharge. In addition, under applicable law, individual supervisors and employees may be subject to personal liability and/or punitive damages in any litigation arising as a result of such conduct.

F. All new hires shall attend harassment awareness training, and supervisors and managers shall attend harassment awareness and prevention training for supervisors every two years.

G. The City of Stockton prohibits retaliation against any employee or non­ employee by another employee, non-employee, supervisor, or manager for reporting, filing, testifying, assisting or participating in any manner in any investigation, proceeding, or hearing conducted by the employer or a federal or state enforcement agency.

H. This policy applies to all officials, employees, volunteers, unpaid interns, agents, or contractors of the City.

I. This policy shall be administered by the Director of Human Resources.

EXHIBIT C

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 3 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment m the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 Ill. DEFINITION AND EXAMPLES OF DISCRIMINATION AND HARASSMENT A. "Discrimination," as used in this policy, is any action, behavior, practice, or process that is intended to deny, or results in the denial of, employment rights, privileges, or benefits because of a person's race, religious creed, color, national origin, ancestry, military and veterans status, physical or mental disability, medical condition, genetic characteristics or information, denial of family and medical care leave, marital status, sexual orientation, sex (including gender, gender identity, gender expression, transgender, pregnancy, childbirth and breastfeeding), political affiliation, age (40 and older), concerted labor activity, or any other prohibition identified under state and federal law. The following are examples of conduct that may constitute discrimination:

1. Soliciting applications from a source where all or most of potential workers are of the
same race or color.

2. Considering a person's gender as the basis for differences in pay, work assignments, performance evaluations, training, discipline, or any other area of employment; and

3. Questioning a job applicant about the existence, nature and severity of a disability.

B. "Harassment," as used in this policy, consists of any conduct affecting another person because of his or her race, religious creed, color, national origin, ancestry, military and veterans status, physical or mental disability, medical condition, genetic characteristics or information, denial of family and medical care leave, marital status, sexual orientation, sex (including gender, gender identity, gender expression, transgender, pregnancy, childbirth and breastfeeding), political affiliation, age (40 and older), concerted labor activity, or any other category or attribute identified under state and federal law when such conduct has the purpose or the effect of: (1) creating an intimidating, hostile or offensive work environment; (2) unreasonably interfering with the employee's or non-employee's work performance; or (3)

EXHIBIT C

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 4 of 14

DISCRIMINATION AND

HARASSMENT POLICY
Effective Date: Revised From:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 otherwise adversely affecting an employee's or non-employee's employment opportunities.

Harassment may take many forms, including, but not limited to, the following examples:

1. Verbal Harassment: Epithets, derogatory and offensive comments or slurs based on race, religion, color, national origin, ancestry, physical or mental disability, marital status, pregnancy, medical condition, gender, sexual orientation, political affiliation, age, or any other category or attribute identified under state and federal law.

2. Physical Harassment: Assault, impeding or blocking movement that results in the physical interference with normal work or movement on the basis of race, religion, color, national origin, ancestry, physical or mental disability, marital status, pregnancy, medical condition, gender, sexual orientation, political affiliation, age, or any other category or attribute identified under state and federal law.

3. Visual Harassment: The displaying of posters, photography, notices, bulletins, e-mails, cartoons or drawings with derogatory and offensive content based on race, religion, color, national origin, ancestry, physical or mental disability, marital status, pregnancy, medical condition, gender, sexual orientation, political affiliation, age, or any other category or attribute
identified under state and federal law.

C. "Sexual harassment," as used in this policy, is a subcategory of harassment, and is specifically defined by law as unwanted sexual advances, requests for sexual favors or visual, verbal or physical conduct of a sexual nature when:

1. Submission to such conduct is made a term or condition of employment; or

2. Submission to or rejection of such conduct is used as a basis for employment decisions affecting the individual; or

EXHIBIT C

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 5 of 14

DISCRIMINATION AND

HARASSMENT POLICY
Effective Date: Revised From:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93

3. Such conduct has the purpose or effect of unreasonably interfering with an employee's or non-employee's work performance or creating an intimidating, hostile or offensive working environment because of the persistent, severe or pervasive nature of the conduct.

Examples of Sexual Harassment include, but are not limited to the following:
a. Unwelcome sexual overtures or propositions.
b. Offering employment benefits or status in exchange for sexual
favors.
c. Making or threatening retaliation after a negative response to sexual advances.
d. Visual conduct such as leering, making sexual gestures, displaying sexually suggestive objects or pictures, cartoons, calendars or posters.
e. Verbal conduct such as using epithets or slurs, telling sexually explicit jokes, or making derogatory or suggestive comments about a person's body or dress.
f. Written communications of a sexual nature distributed in hard copy, soft copy or via a computer network.
g. Verbal abuse of a sexual nature, graphic verbal commentary about an individual's body, sexually degrading words to describe an individual, suggestive or obscene letters, notes or invitations.
h. Physical conduct such as touching, assaulting, impeding or blocking movements.

EXHIBIT C

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 6 of 14
DISCRIMINATION AND Effective Date:

HARASSMENT POLICY
Revised From:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95. 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 i. Retaliation for making harassment reports or threatening to report harassment.

D. Affordable Care Act (ACA) Anti-Retaliation
Pursuant to section §1558 of the Affordable Care Act, the City prohibits discrimination or retaliation towards any employee who:

1. Receives a health insurance tax credit or subsidy through the Health Care "Marketplace" or "Exchange", by which can trigger a penalty payable by the employer;

2. Reports potential violations of protections afforded under Title I of the Act, which provides guaranteed availability protections among other things;

3. Testifies in a proceeding concerning such violation;

4. Assists or participates in a proceeding concerning a violation; or

5. Objects to, or refuses to participate in, any activity, policy, practice, or assigned task that the employee reasonably believes to be in violation of any provision of the Title I of the Act.

An employee who believes that he or she has been discharged or otherwise discriminated against in violation of section §1558 of the Affordable Care Act may seek relief in accordance with the procedures, notifications, burdens of proof, remedies, and statutes of limitation set forth in section 2087(b) of title 15, United States Code.

IV. REPORTING AND COMPLAINT PROCEDURES
A. Immediate Action Required
The City's reporting and complaint procedures provide for an immediate, thorough and objective investigation of discrimination or harassment claims, appropriate disciplinary action taken against any person found to have engaged in prohibited behavior, and appropriate alternative remedies to any

EXHIBIT C

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 7 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 employee or non-employee subject to discrimination or harassment. To accomplish this, such incidents must be reported immediately to a supervisor or manager.

1. Employee's and Non-Employee's Responsibilities when Subjected to Discrimination and/or Harassment
a. Employees or non-employees who believe they have been subjected to discrimination or harassment, or are aware of discrimination or harassment against others, shall report the situation immediately to his/her supervisor or manager, except as specified in subsection (b), below. Employees and non­ employees shall report any such incidents occurring in the workplace, whether committed by coworkers, supervisors or managers, or third persons doing business with the City, such as customers or vendors, or other non-employees. If
comfortable
doing so, an employee or non-employee who has
a complaint of discrimination or harassment is encouraged to directly inform the person(s) engaging in the behavior that such conduct is offensive and insist the behavior to stop.
b. Employees and non-employees must immediately contact a supervisor or manager to register a complaint of discrimination or harassment, unless that supervisor or manager is the individual engaging in the unwanted behavior. In that case, the employee or non-employee may contact someone at the next supervisory level. If the employee or non-employee feels uncomfortable dealing directly with his or her immediate supervisor or manager, he or she may contact the department head, or the Director of Human Resources (or either of their designees) to register a complaint of discrimination or harassment.
c. Employees and non-employees may file a formal complaint of harassment or discrimination with their department head or

EXHIBIT C

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 8 of 14

DISCRIMINATION AND

HARASSMENT POLICY
Effective Date: Revised From:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment In the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 with Human Resources. To assist the City in conducting a thorough investigation, complaints shall be submitted in writing and shall include specific details of the incident(s), the names of the individuals involved, the names of any witnesses, and any documentary evidence (notes,
pictures, cartoons, etc.) that
will corroborate the allegations.
d. Employees and non-employees shall immediately report any retaliation to a supervisor, manager, department head or Director of Human Resources (or designee). All retaliation complaints shall be immediately, objectively and thoroughly investigated in accordance with the investigation procedures.

If a report of retaliation is substantiated, appropriate disciplinary action, up to and including discharge shall be taken.

2. Supervisor's or Manager's Responsibilities to Eliminate Discrimination and/or Harassment
a. A supervisor or manager is responsible for enforcing the City's discrimination and harassment policy. Supervisors or
managers must ensure that all employees and non-employees are aware of the City's policy through open discussion of the policy at staff meetings and by posting the policy in a conspicuous location accessible to all staff members.
b. A supervisor or manager shall be cognizant of employees' and non-employees' behavior and shall not permit any employee or non-employee under their supervision to be subjected to or engage in any conduct prohibited by this policy.
c. A supervisor or manager who observes conduct prohibited by this policy shall immediately direct the employee or non­ employee to cease the conduct.

EXHIBIT C

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 9 of 14
DISCRIMINATION AND Revised From:

HARASSMENT POLICY
Effective Date:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 d. A supervisor or manager who receives a complaint of
prohibited conduct is required to take the complaint seriously, and report the matter
immediately to the department head; be
supportive of the complainant; ensure there is no retaliation against the complainant; conduct an internal fact-finding review into the allegations; obtain as much detailed information as possible; thoroughly document the findings; communicate in written form to the parties the resolution of the complaint; and report to and consult with the Human Resources Department promptly, without delay.

B. Confidentiality. The City will make every effort to protect the privacy and confidentiality of all parties involved, as well as any information and/or documentation obtained, to the extent possible consistent with a thorough investigation.

C. Penalty for Non-Compliance. The City shall take disciplinary action, up to and including discharge, against any supervisor or manager who fails in his/her responsibility to take immediate action in response to an employee's or non-employee's complaint of discrimination or harassment. Further, such disciplinary action shall be taken against a supervisor or manager who fails to stop discriminatory or harassing conduct committed in his/her presence or to stop such conduct about which the supervisor or manager has knowledge.

V. INVESTIGATION PROCEDURES
A. Determination of Responsibility for Investigation
If a formal complaint is filed with the department head or the Director of Human Resources (or either of their designees), the department head and the Director of Human Resources shall consult with one another to determine whether the department or Human Resources shall conduct the fact-finding investigation into the allegations. Either the department head or the Director of Human Resources (or either of their designees), depending on who is

EXHIBIT C

EXHIBIT 2
Subject:

B.

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No.10 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment In the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 responsible for the investigation, shall issue written notification to the complainant and alleged harasser(s). The notification shall specify the nature of the complaint, and inform the parties that an investigation into the allegations of discrimination and/or harassment shall be conducted.

Investigative Guidelines
The investigation shall include the following steps taken in the order best suited to the circumstances:

1. Identify and preserve the evidence.

2. Confirm the name and position of the complainant. Interview the complainant.

3. Allow the complainant the opportunity to place the complaint in writing.

4. Obtain the identity of the alleged harasser(s).

5. Obtain as many details as possible regarding the incident(s) that prompted the complaint, including the number of occurrences, dates, times, locations, and witnesses (if applicable).

6. Ascertain how the complainant felt about the alleged incident when it
occurred; complainant's response(s) to the alleged behavior; and witness statements (if applicable).

7. Ascertain if any threats or promises were made in connection with the alleged harassment.

8. Ascertain if the complainant knows of or suspects that there are other victims of harassment by the same person(s).

9. Ascertain whether the complainant has spoken to anyone, especially

EXHIBIT C

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 11 of 14

DISCRIMINATION AND

HARASSMENT POLICY
Effective Date: Revised From:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment m the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 supervisors, about the harassment.

10. Ascertain what resolution would be acceptable to the complainant.

11. Interview the alleged harasser to get his or her side of the story, including any possible motivation for a false allegation.

12. Interview witnesses who were identified by the complainant regarding the alleged harasser or other persons identified during the investigation.

13. Interview witnesses who were identified by the alleged harasser or other persons identified during the investigation.

14. Advise all participants that the investigation is "confidential" and not to engage in any retaliatory conduct, as such conduct is subject to disciplinary action up to and including discharge. Confidentiality will be maintained to the extent possible. An individual who is interviewed during the course of an investigation is prohibited from discussing the substance of the interview, except as otherwise directed by a supervisor or the Director of Human Resources. Any individual who discusses the content of an investigatory interview will be subject to discipline or other appropriate sanction.

15. Conduct follow-up interviews, if warranted.

16. Prepare report of findings and discuss with management and designated legal staff.

VI. RESPONDING TO THE COMPLAINT
A. Following the completion of the fact-finding investigation, either the department head or the Director of Human Resources (or either of their designees), depending on who is responsible for the investigation, shall

EXHIBIT C

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No.12 of 14
DISCRIMINATION AND Effective Date: Revised From: HARASSMENT POLICY 7/27/09 5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 make a report of findings, along with a recommendation regarding the appropriate remedial action to be taken, if warranted. The recommendation shall be made after reviewing the findings of the investigation, giving consideration to all factual information, the nature of the alleged conduct, and the totality of the circumstances. If the investigation was conducted by the Director of Human Resources, or designee, the Director, or designee, shall confer with the affected department head and both shall concur on the remedial action to be taken, if any. If the investigation was conducted by the department head, the
department head shall confer with the Director of
Human Resources prior to making the report of findings and both shall concur on the remedial action to be taken, if any.

B. If either the department head or the Director of Human Resources does not concur with the findings and recommendation of the other, the City Attorney (or designee) shall review and resolve the matter in dispute.

C. Report of findings and recommendation shall be treated as a confidential document and no other distribution shall be made without first consulting with the City Attorney's Office. A completed investigation report will not be disclosed, except as it is deemed necessary to support a disciplinary action, to take remedial action, to defend the City in adversarial proceedings, or to comply with the law or court order.

D. Either the department head or the Director of Human Resources (or either of their designees), depending on who is responsible for the investigation shall provide a written response to the complainant and the person alleged to have committed the misconduct, discrimination and/or harassment. The response shall include a copy of the City's discrimination and harassment policy and a memorandum indicating the City's determination as to whether the complaint is:

1. Unsustained: The investigation failed to disclose sufficient evidence to substantiate the allegation(s).

2. Unfounded: The investigation proved that the act(s) or omission(s)

EXHIBIT C

EXHIBIT 2

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Subject: Directive No. HR-15 Page No. 13 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09

3. 5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 complained of did not occur. The finding also applies when the individual employee(s) named in the complaint were not involved in the act(s) or omission(s) alleged.

Sustained: The investigation disclosed sufficient evidence to substantiate the allegation(s) made in the complaint; appropriate action will be taken.

E. Details regarding any specific fact-findings or disciplinary action to be taken will not be communicated to the complainant. The City Attorney shall review the response for
legal sufficiency before dissemination.

F. The City shall close and retain the investigation file, in accordance with applicable laws, regulations, and City policy regarding retention of City records.

VII. DISCIPLINE
Disciplinary action imposed as a result of any investigation conducted pursuant to this policy shall be commensurate with the severity of the offense, up to and including discharge, even for a first offense.

VIII. ALTERNATIVE REMEDIES
If upon exhausting all internal remedies to file, investigate, and respond to a charges of discrimination/harassment, pursuant to title VII of the Federal Civil Rights Act of 1964 (42 U.S.C §§ 2000e et seq.), any person has a right to file a charge of discrimination/harassment with the Equal Employment Opportunity Commission ("EEOC"). In addition, pursuant to the California Fair Employment and Housing Act (Gov. Code §§ 12900 - 12996.) a person may also file a complaint of discrimination/harassment with the California Department of Fair Employment and Housing ("DFEH"). Employees or non-employees who believe that they have been subjected to discrimination/harassment may file a complaint with either of these

EXHIBIT C

EXHIBIT 2

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Subject: Directive No. HR-15 Page No. 14 of 14

DISCRIMINATION AND

HARASSMENT POLICY
Effective Date: Revised From:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 agencies. Both the EEOC and DFEH serve as neutral fact-finders and attempt to assist parties in resolving disputes voluntarily.

IX. COMMUNICATION OF POLICY
This policy shall be provided to all managers, supervisors, employees, volunteers, unpaid interns, agents or contractors of the City and shall be posted in the appropriate places. All employees shall participate in City approved harassment
awareness training as directed by management or Human Resources; and all supervisors, as required by law, shall participate in City approved interactive harassment awareness training and education sessions at least once every two years, or as otherwise specified by law.

APPROVED:
c:r��SON

CITY MANAGER
::ODMA\GRPWISE\COS.PER.PER_Library:96180.1

EXHIBIT C

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2

EXHIBIT D

EXHIBIT 2
BOND #107605760

BOND FOR FAITHFUL PERFORMANCE
KNOW ALL MEN BY THESE PRESENTS:

That we, SAK CONSTRUCTION, LLC, a STATE OF MISSOURI
LIMITED LIABLITY COMPANY, as Principal and Travelers cas11a1 tl/ anci s11retll Gomp,my Of America a corporation, organized and existing under the laws of the State of Connecticut and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, as ob Ii gee, in the just and full sum of TWO MILLION TWO

HUNDRED NINETY-ONE THOUSAND SEVEN HUNDRED THIRTY-EIGHT AND NO/100 DOLLARS ($2,291,738.00), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to the said CITY, the said Principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.

The condition of the foregoing obligation is such that the above bounded Principal has simultaneously entered into a contract with the CITY, to do and perform the following work, to wit:

SIERRA NEVADA STREET SANITARY SEWER REHABILITATION
PROJECT NO. UW18029 (FORMERLY M18029)
NOW, THEREFORE, if the above bounded Principal, CONTRACTOR, Company or
Corporation or its subcontractor, shall well and truly perform the work contracted to be done under said contract, then this obligation to be null and void; otherwise to remain in full force and effect.

No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract, or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY, and no forbearance on the part of the said CITY shall operate to relieve any Surety or Sureties from liability on this bond,

EXHIBIT 2
and consent by said Surety is hereby given, and the said Surety hereby waives the provisions of Sections 2819 and 2845 of the Civil Code of the State of California.

SIGNED AND SEALED on._LfJ...f/_..54/.,_.H;'-"'¢:,...._ __________ _ APPROVED AS TO SURETY:

APPROVED AS TO FORM & CONTENT:

LORI M. ASUNCION

OFFICE OF THE CITY ATTORNEY
By:---------­

DEPUTY CITY ATTORNEY
SAK Construction
864 Hoff Road, O Fa on 63366
Travelers Casualty and Surety Company of America
One Tower Square, Hartford, CT 06183
SURETY

ATTORNEY-IN-FACT
Andrew P. Thome, Attorney-in-Fact

EXHIBIT 2
BOND #107605760

BOND FOR LABOR AND MATERIAL
KNOW ALL MEN BY THESE PRESENTS:

That we, SAK CONSTRUCTION, LLC, a STATE OF MISSOURI
LIMITED LIABLITY COMPANY, as Principal and Travelers casualty and surety _c_om�p�a_n=y_o_f_Am_e_r_i_c_a ____ � a corporation, organized and existing under the laws of the State of Connecticut and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, and unto any and all material suppliers, persons, companies, or corporations furnishing materials, provisions, provender or other supplies used in, upon, for or about the performance of the work contemplated to be executed or performed under the contract hereinafter mentioned, and all persons, companies, or corporations renting or hiring teams, or implements of machinery, for or contributing to said work and all persons who perform work or labor upon the same, and all persons who supply both work and materials, and whose claims have not been paid by the contractor, company or corporation in the just and full sum of TWO MILLION TWO HUNDRED NINETY-ONE THOUSAND SEVEN HUNDRED THIRTY-EIGHT AND NO/100 DOLLARS ($2,291,738.00), in lawful money of the United States of America {being 100% of the contract price) for the payment whereof well and truly to be made to said CITY and to said persons jointly and severally, the said principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.

The condition of the foregoing obligations is such that the above bounden Principal has simultaneously entered into a contract of even date herewith, with the CITY, to do and perform the following work, to-wit:

SIERRA NEVADA STREET SANITARY SEWER REHABILITATION
PROJECT NO. UW18029 (FORMERLY M18029)
NOW, THEREFORE, if the above bounden Principal, CONTRACTOR, Company or Corporation or its subcontractor, fail to pay for all materials, provisions, provender, or other supplies, or teams, used in, upon, for or about the performance of the work 1

EXHIBIT 2
contracted to be done, or for any work or labor done thereon of any kind, the Surety on this bond will pay the same, in an amount not exceeding the sum specified in this bond, provided that any and all claims hereunder shall be filed and proceedings had in connection therewith as required by the provisions of Division 3, Part 4, Title 15, Chapter 5, Article 1 of the Civil Code of California, provided that in case suit is brought upon this bond, a reasonable attorney's fee shall be awarded by the Court to the prevailing party in said suit; said attorney's fee to be fixed as costs in said suit, and to be included in the judgment therein rendered.

No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY and no forbearance on the part of the said CITY shall operate to relieve any surety or sureties from liability on this bond, and consent to make such alterations without further notice to or consent by any such surety is hereby given, and the said sureties hereby waive the provisions of Sections 2819 and 2845 of the Civil Code of the State of California.

SIGNED AND SEALED on _Y""-1-/.....;;;s-4-/ =.}.;).=..;.__ _________ ---'- APPROVED AS TO FORM & CONTENT:

LORI M. ASUNCION

OFFICE OF THE CITY ATTORNEY
By:---------­

DEPUTY CITY ATTORNEY
Travelers
One Tower Square, Hartford,
SURETY
pany of America
06183
By:�/�

ATTORNEY-IN-FACT
Andrew P. Thome, Attorney-in-Fact
2

EXHIBIT 2

ACKNOWLEDGEMENT FOR CONTRACTOR

ACKNOWLEDGEMENT FOR CONTRACTOR, IF LIMITED LIABILITY COMPANY STATE OF Missouri }
COUNTY OF St. Charles}
ON THE S: DAYOF -i::.{4:p:If"Lr:-'-i _,_J __ _, 20&;).,,BEFORE ME PERSONALLY APPEARED--'-(;,="''9>fl"'ol'-+fd:,""· "'d:i.::..c ______ TO ME KNOWN AND KNOWN TO ME TO BE THE Pre_sy <l<'=t OF SAK Construction, LLC,

A LIMITED LIABILITY COMPANY, DESCRIBED IN AND WHO EXECUTED THE

FOREGOING INSTRUMENT AND ACKNOWLEDGED TO ME THAT HE

EXECUTED THE FOREGOING INSTRUMENT AND ACKNOWLEDGED TO ME THAT

HE EXECUTED THE SAME AS AND FOR THE ACT AND DEED OF SAID LIMITED LIABILITY COMPANY.

Notary Public

EXHIBIT 2

CALIFORNIA ALL-PURPOSE

CERTIFICATE OF ACKNOWLEDGMENT
w h 1,1111 MissouriState of camorrua
County of St. Louis -----------
On before me, Dana A. Johnessee, Notary Public
-------•('i:fir.e:;;,e;-lilS:;;;;e;;:rt;cn;;:ru:;;n;;:e;-an;;;;;dr;t;;;1t'"le;-o;;:fe"Cth;i;;;e:-;o:.ff.-.,c:c.e::r') -------- ' personally appeared Andrew P. Thome, Attorney-In-Fact -----------�--------------------- who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that be/she/they executed the same in his/her/their authorized capacity(ies), .and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person( s) acted, executed the instrument.

I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. DANA A JOHNESSEE
WITNESS my hand and official seal.
�G..__ & -:-Ti A ----
Signarure of Noti°iyPublic
Dana A. Johnessee, Notary Public

NOTARY PUBLIC - NOTARY SEAL

STATE OF MISSOURI
COMMISSIONED FOR ST. LOUIS COUNTY
MY COMMISSION EXPIRES SEP. 20, 2025. 10#13516439
(Noiary Seal) L---�::..,::�;::.;..::..:.::.=..-------

ADDITIONAL OPTIONAL INFORMATION

DESCRIPTION OF THE ATTACHED DOCUMENT
Bond for Faithful Performance and
Bond for Labor and Material
(Title or description of attached document)
(Title or description ot'attached document continued)
Number of Pages _4_ Document Date 4/s; / J ).

Travelers Casualty and Sureiv Company of America (Adrutmnal mf01mationJ

CAPACITY CLAIMED BY THE SIGNER
0 Individual (s)
0 Corporate Officer
(Title)
Partner(s)
Attorney-in-Fact
Trustee(s)
Other
2008 Ver.;ion CAPA vl2.J0.07 800-873-9865 www.NotaryClasses.com S-4067/GE 9/09
1NSTRUCTIONS FOR COMPLETING THIS F0RlvI
Any acknowledgment comple1ed in California must contain verbiage exactly as appears abolle in tl,e notary section or a separate acknowledgmem fomi must be properly completed and at!aclted to that doamienJ. 171e only exception is if a docwue11t is lo be recorded outside o/Calffornia. ln such instnuCi!S, ar.y alternative aclv,owledgment verbiage as may be prhzted on such a document so long as the verbiage does not require the 11atary to do something !hat is illegal for a notary tn Califomia (i.e. cerzifying the authorized capacity of the siguer). Please d,eck the document carcfitlly for proper ua,�ial wording aJld altach /Iii$ form ifregctircd. • State and Couoty infonnation muSt be the State and County where the document signer(s} pmonally appeared before the notary public for ackno"'!ledgmcnt • Date of notarization must be the date that the signer(s} personally appcered which must also be the same date tl)e acknowledgment is completed.

The ootary public must prinL his ·or her name as it appears within his or her commission followed by a comma and then your title (notary public}. ·• Print tl1e name(s} of document signer(s) who personally appear at the time of notarization.
• indicate the correct singular or plural forms by crossini;:: off inconeet fonns (i.e. he /she/they; is/,-re) or circling: the correct forms. Failure to correctly indicate this information may lead to rejection of document record inc.

The notary seal impression must be clear and photographically reproducible. lmpr:ssion must not cover text or lines. Jf seal impression smudges, re•seal if a sufficient am pennitst otherwise complete a different acknowledgment form. • Signarure of the notary public must match the signature on file wiU1 the office of the county clerk.
❖ Additional infonnation is not required but could help lo ensure this acknowledgmeat is not misused or attached to a different document. ❖ lndicate title or cype of attached doc um enc, number of pages and date. ❖ h1dica1e the capacity claimed by the signer. If the claimed capacity ii • corporate officer, indicate the liUc (i.e. CEO, CFO, Secretary}. ' Securely attach tliis document to tlie si.gned document XDP

EXHIBIT 2
State of Missouri
County of St. Louis
On Y /5 /.;le& , before me, a Notary Public in and for said County and State, residing therein, duly commissioned and sworn, personally appeared Andrew P. Thome known to me to be Attorney-in-Fact of

TRAVELERS CASUALTY AND SURETY COMP ANY OF AMERICA
the corporation described in and that executed the within and foregoing instrument, and known to me to be the person who executed the said instrument in behalf of said corporation, and he duly acknowledged to me that such corporation executed the same.

IN WITNESS WHEREOF, I have hereunto set my hand and affixed my official seal, the day and year stated in this certificate above.

Dana A. Johnessee, Notary Public

DANA A JOHNESSEE
NOTARY PUBLIC· NOTARY SEAL

ST ATE OF MISSOURI
COMMISSIONED FOR ST. LOUIS COUNTY
MY COMMISSION EXPIRES SEP. 20, 2025
ID #13516439
My Commission Expires: _____________ _

EXHIBIT 2
,,... TRAVELERSJ
Travelers Casualty and Surety Company of America
Travelers Casualty and Surety Company
St. Paul Fire and Marine Insurance Company

POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS: That Travelers Casualty and Surety Company of America, Travelers Casualty and Surety Company, and St. Paul Fire and Marine Insurance Company are corporations duly organized under the laws of the State of Connecticut (herein collectively called the "Companies"), and that the Companies do hereby make, constitute and appoint ANDREW P THOME of CHESTERFIELD , Missouri , their true and lawful Attorney(s)-in-Fact to sign, execute, seal and acknowledge any and all bonds, recognizances, conditional undertakings and other writings obligatory in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings a/lowed by Jaw.

IN WITNESS WHEREOF, the Companies have caused this instrument to be signed, and their corporate seals to be hereto affixed, this 21st day of April, 2021.

State of Connecticut
City of Hartford ss.

On this the 21st day of April, 2021, before me personally appeared Robert L. Raney, who acknowledged himself to be the Senior Vice President of each of the Companies, and that he, as such, being authorized so to do, executed the foregoing instrument for the purposes therein contained by signing on behalf of said Companies by himself as a duly authorized officer.

IN WITNESS WHEREOF, I hereunto set my hand and official seal.

My Commission expires the 30th day of June, 2026
("•:�
�;
v \)
�:::�
Anna P. Nowlk, Notary Public
This Power of Attorney is granted under and by the authority of the following resolutions adopted by the Boards of Directors of each of the Companies, which resolutions are now in full force and effect, reading as follows:

RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attorneys-in-Fact and Agents to act for and on behalf of the Company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's name and seal with the Company's seal bonds, recognizances, contracts of Indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking, and any of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her; and it is FURTHER RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President may delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided that each such delegation is in writing and a copy thereof is flied in the office of the Secretary; and it is FURTHER RESOLVED, that any bond, recognizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, or conditional undertaking shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary; or {b) duly executed (under seal, if required) by one or more Attorneys�in-Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority; and it is FURTHER RESOLVED, that the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary, and the seal of the Company may be affixed by facsimile to any Power of Attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys-in­ Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such Power of Attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding on the Company in the future with respect to any bond or understanding to which it is attached.

I, Kevin E. Hughes, the undersigned, Assistant Secretary of each of the Companies, do hereby certify that the above and foregoing Is a true and correct copy of the Power of Attorney executed by said Companies, which remains in full force and effect.

Dated this ,; day of ,¾Jr·, I
lkevin E. Hughes,AssitantSecretary
To verify the authenticity of this Power of Attorney, please call us at 1 ·B00-421-3880.

Please refer to the above-named Attorney{s)-in-Fact and the details of the bond to which this Power of Attorney is attached.

EXHIBIT 2

CASH ANO INVESTED CASH
BONDS
STOCKS

INVESTMENT INCOME DUE AND ACCRUED

OTHER INVESTED ASSETS

PREMIUM BALANCES

NET DEFERRED TAX ASSET

REINSURANCE RECOVERABLE

TRAVELERS CASUAL TY AND SURETY COMPANY OF AMERICA
HARTFORD, CONNECTICUT 06183
FINANCIAL STATEMENT AS OF DECEMBER 31, 2020
CAPITAL STOCK$ 6,480,000
$ 239,403,348 UNEARNED PREMIUMS
3,831,166,861 LOSSES
109,074,035 LOSS ADJUSTMENT EXPENSES
36,856,709 COMMISSIONS
4,970,512 TAXES, LICENSES ANO FEES
277,653,788 OTHER EXPENSES
55,188,715 CURRENT FEDERAL AND FOREIGN INCOME TAXES
32,553,618 REMITTANCES AND ITEMS NOT ALLOCATED
RECEIVABLES FROM PARENT, SUBSIDIARIES AND AFFILIATES 34,876,347 AMOUNTS WITHHELD/ RETAINED BY COMPANY FOR OTHE:R.S

OTHER ASSETS

TOTAL ASSETS

STATE OF CONNECTICUT
COUNTY OF HARTFORD } SS.

CITY OF HARTFORD
4,155,794
• 4,625,68§,621

POLICYHOLDER DIVIDENDS
PROVISION FOR RE:INSURANCE

ADVANCE PREMIUM

CEDED REINSURANCE NET PREMIUMS

PAYABLE

RETROACTIVE REINSURANCE RESERVE ASSUMED

OTHER ACCRUED EXPENSES AND LIABILITIES

TOTAL LIABILITIES
CAPITAL STOCI<

PAID IN SURPLUS

OTHER SURPLUS

TOTAL SURPLUS TO POLICYHOLDERS

TOTAL LIABILITIES & SURPLUS
MICHAEL J. DOODY, BEING DULY SWORN, SAYS THAT HE IS VJCE PRESIDENT-FINANCE, OF TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA,

AND THAT TO THE BEST OF HIS KNOWLEDGE AND BELIEF, THE FOREGOING IS A TRUE AND CORRECT STATEMENT OF THE FINANCIAL CONDITION OF SAID COMPANY AS OF THE 31ST DAY OF DECEMBER, 2020,

SUBSCRIBED AND SWORN TO BEFORE ME THIS
26TH DAY OF MARCH, 2021
SUSAN M. WEISSLEDER
Nota,y Public
lvly Commission Expires November 30, 2022
$ 1,121,070,380
1,003,200,666
163,346,678
48,805,693
13,561,421
42,506,558
4,865,484
8,646,391
42,228,250
12,353,304
7,930,280
1,867,512
63,102,972
800,763
568,668
$2,534,855,020
$6,480,000
433,803,760
1,650,750,847
$2,091,034,607
$4,625,889,627

EXHIBIT 2