EXHIBIT F
EXHIBIT 2
• The Federal Aviation Administration's Nondiscrimination statute (49 U.S.C. § 47123) (prohibits discrimination on the basis of race, color, national origin, and sex);
• Executive Order 12898, Federal Actions to Address Environmental Justice in Minority Populations and Low-Income Populations, which ensures discrimination against minority populations by discouraging programs, policies, and activities with disproportionately high and adverse human health or environmental effects on minority and low-income populations; • Executive Order 13166, Improving Access to Services for Persons with Limited English Proficiency, and resulting agency guidance, national origin discrimination includes discrimination because of limited English proficiency (LEP). To ensure compliance with Title VI, you must take reasonable steps to ensure that LEP persons have meaningful access to your programs (70 Fed. Reg. at 74087 to 74100);
• Title IX of the Education Amendments of 1972, as amended, which prohibits you from discriminating because of sex in education programs or activities (20 U.S.C. 1681 et seq).
EXHIBIT F
EXHIBIT 2
1 BOND FOR FAITHFUL PERFORMANCE
KN
OW ALL MEN BY THESE PRESENTS:
That we, _______________________________, a STA TE OF CA PARTNERSHIP as Principal and
, a corporation, organized and existing under the laws of the State of and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, as obligee, in the just and full sum of FOUR HUNDRED ONE THOUSAND SIX HUNDRED SEVENTY AND 00/100 DOLLARS ($401,670.00), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to the said CITY, the said Principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.
The condition of the foregoing obligation is such that the above bounded Principal has s
imultaneously entered into a contract with the CITY, to do and perform the following work, to wit:
RE
AL-TIME TRAFFIC FLOW MONITORING
PROJECT NO. WT17026 / FEDERAL PROJECT NO. CML-5008(180) N
OW, THEREFORE, if the above bounded Principal, CONTRACTOR, Company or
Corporation or its Subcontractor, shall well and truly perform the work contracted to be done under said contract, then this obligation to be null and void; otherwise to remain in full force and effect.
No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract, or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY, and no forbearance on the part of the said CITY shall operate to relieve any Surety or Sureties from liability on thi s bond, and consent by said Surety is hereby given, and the said Surety hereby waives the EXHIBIT 2
2 provisions of Sections 2819 and 2845 of the Civil Code of the State of California.
S
IGNED AND SEALED on
APPR
OVED AS TO SURETY: By
P RINCIPAL
S URETY
APPR
OVED AS TO FORM & CONTENT:
LORI M. ASUNCION
OFFICE OF THE CITY ATTORNEY
By
A TTORNEY-IN-FACT
By
ACTING CI TY ATTORNEY
EXHIBIT 2
1 BOND FOR LABOR AND MATERIAL
KN
OW ALL MEN BY THESE PRESENTS:
That we, ST. F RANCIS ELECTRIC, LLC, a STATE OF CA PARTNERSHIP , as Principal and , a corporation, organized and existing under the laws of the State of and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, and unto any and all material suppliers, persons, companies, or corporations furnishing materials, provisions, provender or other supplies used in, upon, for or about the performance of the work contemplated to be executed or performed under the contract hereinafter mentioned, and all persons, companies, or corporations renting or hiring teams, or implements of machinery, for or contributing to said work and all persons who perform work or labor upon the same, and all persons who supply both work and materials, and whose claims have not been paid by the contractor, company or corporation in the just and full sum of FOUR HUNDRED ONE THOUSAND SIX HUNDRED SEVENTY AND 00/100 DOLLARS ($401,670.00), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to said City of Stockton and to said persons jointly and severally, the said principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.
The condition of the foregoing obligations is such that the above bounden Principal has s
imultaneously entered into a contract of even date herewith, with the CITY, to do and perform the following work, to-wit:
RE
AL-TIME TRAFFIC FLOW MONITORING
PROJECT NO. WT17026 / FEDERAL PROJECT NO. CML-5008(180) N
OW, THEREFORE, if the above bounden Principal, CONTRACTOR, Company or Corporation or its Subcontractor, fail to pay for all materials, provisions, provender, or other supplies, or teams, used in, upon, for or about the performance of the work contracted to be done, or for any work or labor done thereon of any kind, the Surety on EXHIBIT 2
2 this bond will pay the same, in an amount not exceeding the sum specified in this bond, provided that any and all claims hereunder shall be filed and proceedings had in connection therewith as required by the provisions of Division 3, Part 4, Title 15, Chapter 5, Article 1 of the Civil Code of California, provided that in case suit is brought upon this bond, a reasonable attorney's fee shall be awarded by the Court to the prevailing party in said suit; sa id attorney's fee to be fixed as costs in said suit, and to be included in the judgment therein rendered.
No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY and no forbearance on the part of the said CITY shall operate to relieve any surety or sureties from liability on this bond, and consent to make such alterations without further notice to or consent by any such surety is hereby given, and the said sureties hereby waive the provisions of Sections 2819 and 2845 of the Civil Code of the State of California.
S
IGNED AND SEALED on .
APPR
OVED AS TO SURETY: By
P RINCIPAL
S URETY
APPR
OVED AS TO FORM & CONTENT:
LORI M. ASUNCION
OFFICE OF THE CITY ATTORNEY
By
A TTORNEY-IN-FACT
By
ACTING CI TY ATTORNEY
EXHIBIT 2