Local Co
nstruction Contract – ST. FRANCIS ELECTRIC, LLC – PROJECT NO. WD22006 ( Updated 07/12/22)
CONSTRUCTION CONTRACT
This contract is made and entered into on _____________, by and between ST.
FRANCIS ELECTRIC, LLC , a STATE OF CALIFORNIA CORPORATION, with a business address at 975 CARDEN STREET, SAN LEANDRO, CA 94577 , hereinafter called "CONTRACTOR," and CITY OF STOCKTON, a municipal corporation, hereinafter called "CITY."
W I T N E S S E T H:
WHEREA
S, plans and specifications for the construction of STREETLIGHT POLE REPLACEMENT FY 2021-22 SB1 (PROJECT NO. WD22006) , hereinafter called “PROJECT,” were regularly adopted by Council Resolution No. __________________, on _________________; and
WHEREAS, the contract for said work was regularly awarded to CONTRACTOR, by Council Resolution No. __________________, on ________________.
NOW, THEREFORE, in consideration of the promises and of the mutual covenants herein contained, the parties hereto expressly agree as follows:
CONTRACTOR agrees:
1. SCOPE OF SERVICES. To do the work and furnish all the labor, materials, tools, equipment, and insurance required for the construction of PROJECT in accordance with the plans and specifications adopted on _____________, by Council Resolution No. __________________. The "contract documents," which include the bid documents, project plans, specifications, all letters of clarification, and the City of Stockton Standard Specifications and Plans, are incorporated into and made a part of this contract by this reference to the same extent as if fully set forth.
2. COMPENSATION. To do and perform the work contemplated hereby in a good and workmanlike manner and to furnish all labor, materials, tools, and equipment necessary therefore at the prices specified in Exhibit A, attached hereto and by reference made a part hereof, under the direction of and to the complete satisfaction of the Director of Public Works of the City of Stockton. Total compensation for services and reimbursement for costs shall not exceed $178,600.00, or as otherwise mutually agreed to in a Contract Change Order.
3. INSURANCE. CONTRACTOR shall not commence any work before obtaining, and shall maintain in force at all times during the duration and performance of this contract, the policies of insurance specified in Exhibit B, which is attached to this contract and incorporated by this reference, and as provided in the “contract documents” including Section 7-1.06 of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27, effective September 27, 2016.
EXHIBIT 2
Lo
cal Construction Contract – ST. FRANCIS ELECTRIC, LLC – PROJECT NO. WD22006 ( Updated 07/12/22)
It shall be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be available to the Additional Insured.
Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any insurance policy or proceeds available to the named Insured; whichever is greater.
The Additional Insured coverage under the CONTRACTOR’s policy shall be “primary and non-contributory” and will not seek contribution from the City of Stockton’s insurance or self-insurance and shall be at least as broad as ISO CG 20 01 04 13.
The limits of insurance required in this agreement may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis for the benefit of the City of Stockton (if agreed to in a written contract or agreement) before the City of Stockton’s own insurance or self- insurance shall be called upon to protect it as a named insured.
All self-insured retentions (SIR) must be disclosed to the City’s Risk Management for approval and shall not reduce the limits of liability. Payment Bond in the amount of the self-insured retention (SIR) may be required.
Policies containing any self-insured retention (SIR) provision shall provide or be endorsed to provide that the SIR may be satisfied by either the named insured or the CITY.
The CITY reserves the right to obtain a full certified copy of any insurance policy and endorsements.
Failure to exercise this right shall not constitute a waiver of right to exercise later.
CONTRACTOR shall maintain insurance as required by this contract to the fullest amount allowed by law and shall maintain insurance for a minimum of five years following the completion of this project. In the event contractor fails to obtain or maintain completed operations coverage as required by this agreement, the City at its sole discretion may purchase the coverage required and the cost will be paid by contractor.
CONTRACTOR agrees to include with all Subcontractors in their subcontract the same requirements and provisions of this agreement including the indemnity and insurance requirements to the extent they apply to the scope of the Subcontractor’s work.
Subcontractors hired by CONTRACTOR agree to be bound to CONTRACTOR and the CITY in the same manner and to the same extent as CONTRACTOR is bound to the CITY under the Contract Documents. Subcontractor further agrees to include these same provisions with any Sub-subcontractor. A copy of the CITY Contract Document Indemnity EXHIBIT 2
Local Construction Contract – ST. FRANCIS ELECTRIC, LLC – PROJECT NO. WD22006 ( Updated 07/12/22)
and Insurance provisions will be furnished to the Subcontractor upon request. The General CONTRACTOR shall require all sub-contractors to provide a valid certificate of insurance and the required endorsements included in the agreement prior to commencement of any work and contractor will provide proof of compliance to the City.
4. INDEMNITY AND HOLD HARMLESS. With the exception that this section shall in no event be construed to require indemnification by Contractor to a greater extent than permitted under the public policy of the State of California, Contractor shall indemnify, protect, defend with counsel approved by City and at Contractor’s sole cost and expense, and hold harmless City, its Mayor, Council, officials, representatives, agents, employees, and volunteers from and against any and all claims, causes of action, liabilities, judgments, awards, losses, liens, claims, stop notices, damages, expenses, and costs (including without limitation attorneys’ fees, expert and consultant fees, and other expenses of litigation) of every nature, including, but not limited to, death or injury to persons, or damage to property, which arise out of or are in any way connected with the work performed, materials furnished, or services provided under this Agreement, or from any violation of any federal, State, or municipal law or ordinance, or City Policy, by Contractor or Contractor’s officers, agents, employees, volunteers or subcontractors.
Contractor shall not be obligated to indemnify or defend City for claims finally determined by a court of law or arbitrator to arise from the active negligence or willful misconduct of the City. It is the intent of the Parties that this indemnity obligation is at least as broad as is permitted under California law. To the extent California Civil Code sections 2782, et seq., limit the defense or indemnity obligations of Contractor to City, the intent hereunder is to provide the maximum defense and indemnity obligations allowed by Contractor under the law. The indemnity set forth in this section shall not be limited by insurance requirements or by any other provision of this Agreement.
With exception that this section shall in no event be construed to require indemnification, including the duty to defend, by Contractor to a greater extent than permitted under the public policy of the State of California, the parties agree that Contractor’s duty to defend City is immediate and arises upon the filing of any claim against the City for damages which arise out of or are in any way connected with the work performed, materials furnished, or services provided under this Agreement by Contractor or Contractor’s officers, agents, employees, volunteers or subcontractors. Contractor’s duties and obligations to defend the City shall apply regardless of whether or not the issue of the City’s liability, breach of this Agreement, or other obligation or fault has been determined.
Contractor shall be immediately obligated to pay for City’s defense costs of the claim, including, but not limited to, court costs, attorney’s fees and costs, expert consultant and witness fees and costs, other witness fees, document reproduction costs, arbitration fees, and, if after final judgment an appeal is pursued, all of such costs for the appeal.
At the conclusion of the claim, if there is any determination or finding of sole active negligence or willful misconduct on the part of the City, City will then reimburse Contractor for amounts paid in excess of Contractor’s proportionate share of responsibility for the damages within 30 days after Contractor provides City with copies of all bills and expenses incurred in the defense of the claim(s). It is agreed between the EXHIBIT 2
Lo
cal Construction Contract – ST. FRANCIS ELECTRIC, LLC – PROJECT NO. WD22006 ( Updated 07/12/22)
parties that this reimbursement provision assures Contractor is not obligated to defend or indemnify City in an amount greater than provided for under California law, including, without limitation, California Civil Code sections 2782, 2782.6, and 2782.8.
With the exception that this section shall in no event be construed to require indemnification by Contractor to a greater extent than permitted under the public policy of the State of California, and in addition to the other indemnity obligations in this Agreement, Contractor shall indemnify, defend, and hold harmless City, its Mayor, Council, officials, representatives, agents, employees, and volunteers from and against all claims, losses, expenses, and costs including, but not limited to, attorneys’ fees, arising out of any claim brought against the City by an employee, office, agent, or volunteer of Contractor, regardless of whether such claim may be covered by any applicable workers compensation insurance. Contractor’s indemnification obligation is not limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for the Contractor under workers’ compensation acts, disability acts, or other employee benefit acts.
The City’s acceptance of the insurance certificates required under this Agreement does not relieve the CONTRACTOR from its obligation under this paragraph. The indemnification obligations of this section shall survive the termination of this agreement.
Any exceptions to this language may result in a proposal being deemed non-responsive.
CONTRACTOR/Subcontractor's responsibility for such defense and indemnity obligations shall survive the termination or completion of this agreement for the full period of time allowed by law.
The defense and indemnification obligations of this agreement are undertaken in addition to, and shall not in any way be limited by, the insurance obligations contained in this agreement. If any section, subsection, sentence, clause or phrase of this indemnification is for any reason held to be invalid or unconstitutional, such decision shall not affect the validity of the remaining portions of this indemnification.
5. STANDARD PLANS AND SPECIFICATIONS. The performance of said work and the furnishing of said materials shall be executed in accordance with Section 8-
1.04B of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27-1213, effective September 27, 2016, and the provisions of the issued project specifications.
The Director of Public Works will furnish CONTRACTOR a weekly statement showing the number of days charged to the contract for the preceding week, the number of days specified for completion of the contract, and the number of days remaining to complete the contract. CONTRACTOR will be allowed one (1) week in which to file a written protest setting forth in what respects said weekly statement is incorrect, otherwise the statement shall be deemed to have been accepted by CONTRACTOR as correct.
EXHIBIT 2
Lo
cal Construction Contract – ST. FRANCIS ELECTRIC, LLC – PROJECT NO. WD22006 ( Updated 07/12/22)
6. WORKING DAYS. This work shall be diligently prosecuted to completion before the expiration of 40 WORKING DAYS beginning on the tenth calendar day after the date shown on the Notice to Proceed. It is agreed by the parties to the contract that in case all the work called for under the contract in all parts and requirements, is not finished or completed within the number of days as set forth, damage will be sustained by the CITY, and that it is and will be impracticable and extremely difficult to ascertain the actual damage which CITY will sustain in the event of and by reason of such delay; and it is therefore agreed that CONTRACTOR will pay to CITY the sum of NINE HUNDRED AND NO/100 DOLLARS ($900.00) per day for each and every calendar days delay in finishing the work in excess of the number of days prescribed; and CONTRACTOR agrees to pay said liquidated damages as herein provided, and in case the same are not paid, agrees that CITY, may deduct the amount thereof from any monies due or that may become due CONTRACTOR under the contract.
It is further agreed that in case the work called for under the contract is not finished and completed in all parts and requirements within the number of days as specified, the CITY shall have the right to increase the number of days or not, as may seem best to serve the interest of CITY, and if the CITY decides to increase the said number of days, the CITY shall further have the right to charge to CONTRACTOR, CONTRACTOR's heirs, assigns or sureties, and to deduct from the final payment for the work, all or any part, as may be deemed proper, the liquidated damages as specified or the actual cost of engineering, inspection, superintendence, and other overhead expenses which are directly chargeable to the contract, and which accrue during the period of such extension, whichever is greater, except the cost of final surveys and preparation of final estimate shall not be included in such charges.
A working day shall not include, nor shall CONTRACTOR be assessed with liquidated damages nor the additional cost of engineering and inspection during any delay beyond the time named for the completion of the work caused by acts of God or of the public enemy, acts of CITY, fire, floods, epidemics, quarantine restrictions, strikes, and freight embargoes and subject to approval by the Director of Public Works, inability to get materials ordered by CONTRACTOR or subcontractor due to such causes provided that CONTRACTOR shall notify the Director of Public Works in writing of the causes of delay within five (5) working days from the beginning of any such delay, and the Director shall ascertain the facts and the extent of the delay, and Director's findings of the facts thereon shall be final and conclusive.
If CONTRACTOR is delayed by reason of alterations made in these specifications, or by any act of the Director of Public Works or of the CITY, not contemplated by the contract, the time of completion shall be extended proportionately and CONTRACTOR shall be relieved during the period of such extension of any claim for liquidated damages, engineering or inspection charges or other penalties. CONTRACTOR shall have no claim for any other compensation for any such delay.
EXHIBIT 2
Lo
cal Construction Contract – ST. FRANCIS ELECTRIC, LLC – PROJECT NO. WD22006 ( Updated 07/12/22)
7. CONFORMANCE TO APPLICABLE LAWS. Contractor shall comply with all applicable Federal, State, and Municipal laws, rules, and ordinances. Contractor shall not discriminate in the employment of persons or in the provision of services under this Contract on the basis of any legally protected classification, including race, color, national origin, ancestry, sex or religion of such person.
a. TITLE VI
T
itle VI of the Civil Rights Act of 1964 requires that “no person in the United States shall, on the grounds of race, color, or national origin, be excluded from participation in, be denied the benefits of, or be subjected to discrimination under any program or activity receiving federal financial assistance.” (42 USC Section 2000d)
http://www.dol.gov/oasam/regs/statutes/titlevi.htm.
T
he City of Stockton requires compliance with the requirements of Title VI in all of its programs and activities regardless of funding source. b. DISCRIMINATION AND HARASSMENT POLICY
T
he City of Stockton has a Discrimination and Harassment Policy (Exhibit C). The purpose of this policy is to reaffirm the CITY’s commitment to demonstrating respect for all individuals by strictly prohibiting discrimination and harassment, including sexual harassment in the workplace, to define the types of behavior and conduct prohibited by this policy, and to set forth a procedure for reporting, investigating, and resolving complaints of discrimination and harassment in the workplace.
c. LABOR STANDARDS PROVISIONS/CALIFORNIA LABOR CODE
T
he bidder shall understand that conditions set forth in Chapter 1, Part 7, Division 2 of the California Labor Code shall be considered part of the contract agreement.
https://leginfo.legislature.ca.gov/faces/codes displayText.xhtml?lawCode= LAB&division=2.&title=&part=7.&chapter=1.&article=2.
d.
PREVAILING WAGE
CO
NTRACTOR and any subcontractor shall pay each employee engaged in the trade or occupation not less than the prevailing hourly wage rate. In accordance with the provisions of Section 1770 of the Labor Code, the Director of Department of Industrial Relations of the State of California has determined the general prevailing wage and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for in Section 1773.1, apprenticeship or other training programs EXHIBIT 2
Lo
cal Construction Contract – ST. FRANCIS ELECTRIC, LLC – PROJECT NO. WD22006 ( Updated 07/12/22)
authorized by Section 3093 and similar purposes applicable to the work to be done. CONTRACTOR performing the work under this contract shall obtain a copy of the wage rate determination and shall distribute copies to each subcontractor. As the wage determination for each craft reflects an expiration date, it shall be the prime CONTRACTOR and each subcontractor's responsibility to ensure that the prevailing wage rates of concern is current and paid to the employee.
i. The CONTRACTOR performing the work shall be responsible for obtaining a copy of the State wage rate determination. State wage rates may be obtained at
http://www.dir.ca.gov/OPRL/pwd/Determinations/Northern/Northern.pd f. The CONTRACTOR shall be responsible for posting said wage rates at a prominent location at the work site and shall maintain same in a good readable condition for the duration of the work.
ii. Should the CONTRACTOR choose to work on a Saturday, Sunday or on a holiday recognized by the Labor Unions, the CONTRACTOR shall reimburse the CITY the actual cost of engineering, inspection, superintendence, and or other overhead expenses which are directly chargeable to the contract. Should such work be undertaken at the request of the CITY, reimbursement will not be required. To conform strictly with the provisions of Division 2, Part 7, Chapter 1, Article 2, of the Labor Code of the State of California. To forfeit as a penalty to CITY the sum of TWENTY-FIVE AND NO/100 DOLLARS ($25.00) for each laborer, worker, or mechanic employed by CONTRACTOR, or by any subcontractor under CONTRACTOR, in the execution of this contract, for each calendar day during which any laborer, worker, or mechanic is required or permitted to work more than eight (8) hours and who is not paid the general prevailing rate of per diem wages for holiday and overtime work in violation of the provisions of Sections 1770 to 1781 of the Labor Code of the State of California. That all sums forfeited under the provisions of the foregoing sections shall be deducted from the payments to be made under the terms of this contract.
iii. The CONTRACTOR to whom the contract is awarded shall ensure that the prime and each subcontractor will in accordance with Section 1776 of the Labor Code, maintain certified payroll records. A copy of said records shall be provided with each invoice to the Public Works Department, Attention Contract Compliance Officer. It shall be the CONTRACTOR’S responsibility to obtain copies of the current prevailing wage rate determination for all subcontractors. Additionally, certified payroll records must be uploaded to the DIR website as required by labor code.
EXHIBIT 2
Lo
cal Construction Contract – ST. FRANCIS ELECTRIC, LLC – PROJECT NO. WD22006 ( Updated 07/12/22)
iv. The CONTRACTOR shall comply with the provisions established in Section 1777.5 of the Labor Code concerning the 1) certified approval by local joint apprenticeship committees for the employment and training of apprentices, and 2) contribution of funds to administer and conduct apprenticeship programs, if applicable to the job. e. LOCAL EMPLOYMENT ORDINANCE
P
ursuant to Stockton Municipal Code Section 3.68.095 the CONTRACTOR and all subcontractors shall make a good faith effort to employ at least 50 percent of the workforce on this project from local residents, as measured by total labor work hours. Failure of any CONTRACTOR or subcontractor to comply with these requirements shall be deemed a material breach of the contract or subcontract. CONTRACTORS and subcontractors shall maintain records necessary for monitoring their compliance with section
3.68.095.
f. SANCTIONS
Deliverabl
es must conform with all applicable federal, state, and local laws. Such conformity includes compliance with federal sanctions, and Contractor certifies that it has not and will not engage in prohibited transactions with sanctioned persons or entities.
CITY agrees:
8. COMPENSATION. To pay CONTRACTOR for the work herein
contemplated in the following manner: Progress payments will be made on or about the first day of each calendar month, in such sum as shall make the aggregate of payment up to such day equal to ninety-five percent (95%) of the proportional contract price, upon the basis of the progress certificate of the Director of Public Works as to the amount of work done and the proportional amount of the contract price represented therefore; and all of the remaining part of the contract price not as aforesaid paid, shall be paid at the expiration of thirty-five (35) days from the completion of said work of construction and the certification by the Director of Public Works of such completion.
9. SECURITIES. Pursuant to Section 22300 of the Public Contract Code, CONTRACTOR will be permitted, at its request and sole expense, to substitute securities for any monies withheld by the CITY to ensure performance under the contract. Said securities will be deposited either with the CITY or with a State or federally chartered bank as escrow agent. Securities eligible for this substitution are those listed in Section 16430 of the California Government Code or bank or savings and loan certificates of deposit.
CONTRACTOR shall be the beneficial owner of any securities substituted for monies withheld and shall receive any interest thereon.
EXHIBIT 2
Lo
cal Construction Contract – ST. FRANCIS ELECTRIC, LLC – PROJECT NO. WD22006 ( Updated 07/12/22)
10. CHANGE ORDERS. CITY reserves the right to make such alterations, deviations, additions to or omissions from the plans and specifications, including the right to increase or decrease the quantity of any item or portion of the work, as may be deemed by the Engineer to be necessary or advisable and to require such extra work as may be determined by the Engineer to be required for the proper completion or construction of the whole work contemplated.
Any such changes will be set forth in a contract change order which will specify, in addition to the work done in connection with the change made, adjustment of contract time, if any, and the basis of compensation for such work. A contract change order will not become effective until approved by the City Manager and/or the City Council.
Processing of change orders shall be in accordance with Section 4-1.05A of the City of Stockton Standard Specifications and Plans as adopted by Council on September 27, 2016, by Resolution No. 2016-09-27-1213, effective September 27, 2016, or as otherwise amended by Council. When the compensation for an item of work is subject to adjustment under the provisions of Standard Specifications and Plans, Section 4-1.05A, CONTRACTOR shall, upon request, promptly furnish the Engineer with adequate detailed cost data for such item of work.
11. AUDITS. CITY reserves the right to periodically audit all charges made by CONTRACTOR to CITY for services under the contract. Upon request, CONTRACTOR agrees to furnish CITY, or a designated representative, with necessary information and assistance.
CONTRACTOR agrees that CITY or its delegate will have the right to review, obtain and copy all records pertaining to performance of the contract. CONTRACTOR agrees to provide CITY or its delegate with any relevant information requested and shall permit CITY or its delegate access to its premises, upon reasonable notice, during normal business hours for the purpose of interviewing employees and inspecting and copying such books, records, accounts, and other material that may be relevant to a matter under investigation for the purpose of determining compliance with this requirement.
CONTRACTOR further agrees to maintain such records for a period of three (3) years after final payment under the contract.
//
//
//
//
//
//
//
//
//
//
EXHIBIT 2
EXHIBIT 2
STREETLIGHT POLE REPLACEMENT
FY 2021-22 SB1
PROJECT NO. WD22006
BIDD ING SCHEDULE
Each bidder shall bid each item, including all alternate bid(s). Failure to bid an item shall be just cause for considering the bid as non-responsive. Line item costs should include all Contractor's overhead and profit and indirect costs. Bids not presented on City forms shall be cause for considering the bid as non-responsive.
Item Descrip ti on Unit Quantity Unit price Total Price 1 Mobilization LS 1 5,000.00 5,000.00
2 Traffic Control LS 1 5,000.00 5,000.00
3 Erosion Control LS 1 $7,600.00 $7,600.00
Remove Existing Light Pole,
4 Equipment & Foundation (Existing LED EA 10 4,500.00 45,000.00 fixtures to be reused) 5 Install Type 15 Street Light Foundation EA 10 4,000.00 including Pull Box 40,000.00 Install New Streetlight Pole with Mast
6 Arm (Reuse existing LED fixtures from EA
removed poles)
10 7,600.00 76,000.00
TOTAL BID $178,600.00
BIDDER'S NAME __ St.Fran_c_is_E_lect_ri __ G __ , LLC __ _ Bid Forms Last Revised 12/31/20
EXHIBIT A
EXHIBIT 2
NOTE: The City of Stockton is now using the online insurance program PINS Advantage. Once you have been awarded a contract you will receive an email from the City’s online insurance program requesting you to forward the email to your insurance provider(s). Please see attached flyer regarding PINS Advantage.
Insurance Requirements for Construction Contracts
Contractor shall procure and maintain for the duration of the contract, and for five (5) years thereafter, insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, their agents, representatives, employees, or subcontractors. In the event contractor fails to obtain or maintain completed operations coverage as required by this agreement, the City, at its sole discretion, may purchase the coverage required and the cost will be paid by the contractor.
MINIMUM SCOPE AND LIMIT OF INSURANCE
Coverage shall be at least as broad as:
1. Commercial General Liability (CGL): Insurance Services Office (ISO) Form CG 00 01 covering CGL on an “occurrence” basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $2,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit.
2. Automobile Liability: Insurance Services Office Form CA 0001 covering Code 1 (any auto), with limits no less than $2,000,000 per accident for bodily injury and property damage.
3. Workers’ Compensation insurance as required by the State of California, with Statutory Limits, and Employers’ Liability insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.
4. Surety Bonds as described below.
It shall be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be available to the Additional Insured. Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any Insurance policy or proceeds available to the named insured; whichever is greater. No representation is made that the minimum insurance requirements of this agreement are sufficient to cover the obligations of the Contractor under this agreement.
EXHIBIT B
EXHIBIT 2
Limits of Insurance
The limits of insurance required in this agreement may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis before the City’s own insurance or self-insurance shall be called upon to protect it as a named insured.
Other Insurance Provisions
The insurance policies are to contain, or be endorsed to contain, the following
provisions:
Additional Insured Status
The Cit
y of Stockton, its officers, officials, employees, and volunteers are to be covered as additional insureds on the CGL policy with respect to liability arising out of work or operations performed by or on behalf of the Contractor including materials, parts, or equipment furnished in connection with such work or operations. General liability coverage can be provided in the form of an endorsement to the Contractor’s insurance (at least as broad as ISO Form CG 20 10 11 85 or if not available, through the addition of both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 if a later edition is used). Additional insured Name of Organization shall read “City of Stockton, its officers, officials, employees, and volunteers.” Policy shall cover City of Stockton, its officers, officials, employees, and volunteers for all locations work is done under this contract.
Primary Coverage
The Addit
ional Insured coverage under the Contractor’s policy shall be “primary and non-contributory” and will not seek contribution from the City’s insurance or self- insurance and shall be at least as broad as CG 20 01 04 13. The City of Stockton does not accept endorsements limiting the Contractor’s insurance coverage to the sole negligence of the Named Insured.
Claims Made Policies – (Note – applicable only to professional and/or pollution liability)
If a
ny coverage required is written on a claims-made coverage form:
1. The retroactive date must be shown, and this date must be before the execution date of the contract or the beginning of contract work.
EXHIBIT B
EXHIBIT 2
2. Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of contract work.
3. If coverage is canceled or non-renewed, and not replaced with another claims-made policy form with a retroactive date prior to the contract effective, or start of work date, the Contractor must purchase extended reporting period coverage for a minimum of five (5) years after completion of contract work.
4. A copy of the claims reporting requirements must be submitted to the City of Stockton for review.
5. If the services involve lead-based paint or asbestos identification/remediation, the Contractors Pollution Liability policy shall not contain lead-based paint or asbestos exclusions. If the services involve mold identification/remediation, the Contractors Pollution Liability policy shall not contain a mold exclusion, and the definition of Pollution shall include microbial matter, including mold.
Notice of Cancellation
Each ins
urance policy required above shall provide that coverage shall not be canceled, except with notice to the City of Stockton.
Waiver of Subrogation
Contractor
hereby grants to City of Stockton a waiver of any right to subrogation which any insurer of said Contractor may acquire against the City of Stockton by virtue of the payment of any loss under such insurance. Contractor agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation, but this provision applies regardless of whether or not the City of Stockton has received a waiver of subrogation endorsement from the insurer. The Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of the City of Stockton for all work performed by the Contractor, its employees, agents and subcontractors.
Self-Insured Retentions
All Self-
insured retentions must be disclosed to Risk Management for approval and shall not reduce the limits of liability. The City of Stockton may require the Contractor to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention.
The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the named insured or City of Stockton.
Acceptability of Insurers
EXHIBIT B
EXHIBIT 2
Insurance is to be placed with insurers with a current A.M. Best’s rating of no less than A:VII, unless otherwise acceptable to the City of Stockton.
Verification of Coverage
Contractor shall furnish the City of Stockton with original certificates and amendatory endorsements or copies of the applicable policy language effecting coverage required by this clause. All certificates and endorsements are to be received and approved by the City of Stockton Risk Services bef
ore work commences. However, failure to obtain the
required documents prior to the work beginning shall not waive the Contractor’s obligation to provide them. The City of Stockton reserves the right to require complete, certified copies of all required insurance policies, including endorsements required by these specifications, at any time.
Contractor shall, prior to the commencement of work under this Agreement, provide the City of Stockton with a copy of its declarations page(s) and endorsement page(s) for each of the required policies.
Subcontractors
Contractors shall require and verify that all subcontractors, or other parties hired for this work, purchase and maintai
n coverage for indemnity and insurance requirements
as least as broad as specified in this agreement to the extent they apply to the scope of the subcontractor’s work with the same certificate of insurance requirements and naming as additional insureds all parties to this contract. Contractor shall include the following language in their agreement with Subcontractors: Subcontractors hired by Contractor agree to be bound to Contractor and City in the same manner and to the same extent as Contractor is bound to City under the contract documents and provide a valid certificate of insurance and the required endorsements included in the agreement as proof of compliance prior to commencement of any work and to include this same requirement for any subcontractors they hire for this work. A copy of the owner contract document indemnity and insurance provisions will be furnished to the subcontractor upon request. Contractor shall provide proof of such compliance and verification to the City upon request.
Surety Bonds
Contractor shall provide the following Surety Bonds:
1. Bid bond
2. Performance bond
EXHIBIT B
EXHIBIT 2
3. Payment bond (or Labor and Material bond)
4. Maintenance bond
The Payment Bond and the Performance Bond shall be in a sum equal to one hundred percent (100%) of the contract price. If the Performance Bond provides for a one-year warranty a separate Maintenance Bond is not necessary. If the warranty period specified in the contract is for longer than one year a Maintenance Bond equal to 10% of the contract price is required. Bonds shall be duly executed by a responsible corporate surety, authorized to issue such bonds in the State of California and secured through an authorized agent with an office in California.
Special Risks or Circumstances
City of Stockton reserves the right to modify these requirements, including limits, based on the natu
re of the risk, prior experience, insurer, coverage, or other special circumstances.
Certificate Holder Address
Proper address for mailing certificates, endorsements and notices shall be:
City of Stockton
Attn: City Risk Services
400 E Main Street, 3rd Floor – HR
Stockton, CA 95202
EXHIBIT B
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2