Local Construction Contract – GEORGE REED, INC. – PROJECT NO. WT18005 (Updated 07/12/22)
CONSTRUCTION CONTRACT
This contract is made and enter ed into on _____________, by and between GEORGE REED, INC., a STAT E OF CA CORPORATION, with a business address at P. O. BOX 4760, MODESTO, CA 95352, hereinafter called "CONTRACTOR," and CITY OF STOCKTON, a municipal corporation, hereinafter called "CITY." W I T N E S S E T H:
WHEREAS,
plans and specifications for the construction of CALIFORNIA STREET
ROAD DIET (PROJECT NO. WT18005/ATPSB1L-5008(194)), hereinafter called “PROJECT,” were regularly adopted by Council Resolution No. __________________, on _________________; and
WHEREAS, the contract
for said work was regularly awarded to CONTRACTOR,
by Council Resolution No. __________________, on ________________.
NOW, THEREFORE, in consideration of the promises and of the mutual covenants herein contained, the parties hereto expressly agree as follows:
CONTRACTOR agrees:
1. SCOPE OF SERVICES. To do the work and furnish all the labor, materials, tools, equipment, and insurance required for the construction of PROJECT in accordance with the plans and specificat ions adopted on _____________, by Council Resolution No. __________________ . The "contract documents, " which include the bid documents, project plans, specifications, all letters of clarification, and the City of Stockton Standard Specifications and Plans, are incorporated into and made a part of this contract by this reference to the same extent as if fully set forth.
2. COMPENSATION. To do and perform the work contemplated hereby in a good and workmanlike manner and to furnish all labor, materials, tools, and equipment necessary therefore at the prices specified in Exhibit A, attached hereto and by reference made a part hereof, under the direction of and to the complete satisfaction of the Director of Public Works of the Cit y of Stockton. Total compensation for services and reimbursement for costs shall not exceed $9,446,626.00, or as otherwise mutually agreed to in a Contract Change Order.
3. INSURANCE. CONTRACTOR shall not commence any work before obtaining, and shall maintain in force at all times during the duration and performance of this contract, the policies of insurance specif ied in Exhibit B, which is attached to this contract and incorporated by this reference, and as provided in the “contract documents” including Section 7-1.06 of the City of Stockt on Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No . 2016-09-27, effective September 27, 2016.
It shall be a requirement under this agreement that any av ailable insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be available to the Additional Insured.
EXHIBIT 2
Local Construction Contract – GEORGE REED, INC. – PROJECT NO. WT18005 (Updated 07/12/22)
Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any insurance policy or proceeds available to the named Insured; whichever is greater.
The Additional Insured coverage under the CONTRACTOR’s policy shall be “primary and non-contributory” and will not seek contribution from the City of Stockton’s insurance or self-insurance and shall be at least as broad as ISO CG 20 01 04 13.
The limits of insurance requir ed in this agreement may be sati sfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contai n a provision that such co verage shall also apply on a primary and non-contributory basis for the benefit of the City of Stockton (if agreed to in a written contract or agreem ent) before the City of Stockton’s own insurance or self- insurance shall be called upon to protect it as a named insured.
All self-insured retentions (SIR) must be disclosed to the CITY’s Risk Management for approval and shall not reduce t he limits of liability. Payment Bond in the amount of the self-insured retention (SIR) may be required.
Policies containing any self-insured retention (SIR) provision shall provide or be endorsed to provide that the SIR may be satisfied by either the named insured or the CITY.
The CITY reserves the right to obtain a full certified copy of any insurance policy and endorsements.
Failure to exercise this right shall not constitute a waiver of right to exercise later.
CONTRACTOR shall maintain insurance as required by this contract to the fullest amount allowed by law and shall maintain insurance for a minimum of five years following the completion of this project. In the event cont ractor fails to obtain or maintain completed operations coverage as requir ed by this agreement, the City at its sole discretion may purchase the coverage required and the cost will be paid by contractor.
CONTRACTOR agrees to include with all Subcont ractors in their subcontract the same requirements and provisions of this agreement including the indemnity and insurance requirements to the extent they apply to the scope of the Subcontractor’s work.
Subcontractors hired by CONTRACTOR ag ree to be bound to CONTRACTOR and the CITY in the same manner and to the same extent as CONTRACTOR is bound to the CITY under the Contract Documents. Subcontractor further agrees to include these same provisions with any Sub-subcontractor. A copy of the CITY Contract Document Indemnity and Insurance provisions will be furnished to the Subcontractor upon request. The General CONTRACTOR shall require all sub-contractors to provide a valid certificate of insurance and the required endorsements included in the agreement prior to commencement of any work and contractor will provide proof of compliance to the City.
EXHIBIT 2
Local Construction Contract – GEORGE REED, INC. – PROJECT NO. WT18005 (Updated 07/12/22)
4. INDEMNITY AND HOLD HARMLESS. With the exception that this section shall in no event be construed to require indemnification by Contractor to a greater extent than permitted under the public policy of the State of California, Contractor shall indemnify, protect, defend with counsel approved by City and at Contractor’s sole cost and expense, and hold harmless City, its Mayo r, Council, official s, representatives, agents, employees, and volunteers from and against any and all claims, causes of action, liabilities, judgments, awar ds, losses, liens, claims, stop notices, damages, expenses, and costs (including without limitation attorne ys’ fees, expert and consultant fees, and other expenses of litigation) of every nature, including, but not limited to, death or injury to persons, or damage to prope rty, which arise out of or are in any way connected with the work performed, ma terials furnished, or services provided under this Agreement, or from any violation of any federal, State, or municipal law or ordinance, or City Policy, by Contractor or Contractor’s of ficers, agents, employees, volu nteers or subc ontractors.
Contractor shall not be obligated to indemnify or defend City for claims finally determined by a court of law or arbitrat or to arise from the active negligence or willful misconduct of the City. It is the intent of the Parties that this indemnity obligation is at least as broad as is permitted under California law. To the extent Califo rnia Civil Code sections 2782, et seq., limit the defense or indemnity obligations of Cont ractor to City, the intent hereunder is to provide the maximum defens e and indemnity obligations allowed by Contractor under the law. The indemnity set forth in this section shall not be limited by insurance requirements or by any other provision of this Agreement.
With exception that this section shall in no event be construed to require indemnification, including the duty to defend, by Contractor to a gr eater extent than permitted under the public policy of the State of California, the parties agree that Contractor’s duty to defend City is immediate and arises upon the filing of any clai m against the City for damages which arise out of or are in any way co nnected with the work performed, materials furnished, or services provided under this Ag reement by Contractor or Contractor’s officers, agents, employees, vo lunteers or subcontractors. Contractor’s duties and obligations to defend the City shall apply regardless of whethe r or not the issue of the City’s liability, breach of this Agreement, or other obligation or fault has been determined.
Contractor shall be immediat ely obligated to pay for City’s defense costs of the claim, including, but not limited to, court costs, attorney’s fees and costs, expert consultant and witness fees and costs, othe r witness fees, document repr oduction costs, arbitration fees, and, if after final judgm ent an appeal is pursued, all of such costs for the appeal.
At the conclusion of the claim, if there is any determination or finding of sole active negligence or willful misconduct on the part of the City, Cit y will then reimburse Contractor for amounts paid in excess of Contractor’s pr oportionate share of responsibility for the damages wi
thin 30 days after Contractor prov ides City with copies of all bills and expenses incurred in the defense of the claim(s). It is agreed between the parties that this reimbursemen t provision assures Contractor is not obligated to defend or indemnify City in an amount greater than provided for under California law, including, without limitation, California Civil Code sections 2782, 2782.6, and 2782.8.
EXHIBIT 2
Local Construction Contract – GEORGE REED, INC. – PROJECT NO. WT18005 (Updated 07/12/22) With the exception that this section sh all in no event be construed to require indemnification by Contractor to a greater extent than pe rmitted under the public policy of the State of California, and in addition to the other i ndemnity obligations in this Agreement, Contractor shall indemnify, de fend, and hold harmle ss City, its Mayor, Council, officials, representatives, agents , employees, and volunt eers from and against all claims, losses, expenses, and costs includi ng, but not limited to, attorneys’ fees, arising out of any claim br ought against the City by an employee, office, agent, or volunteer of Contractor, r egardless of whether such claim may be covered by any applicable workers compensation insurance. Contractor’s indemnification obligation is not limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for the Contractor under workers’ compensation acts, disability acts, or other employee benefit acts.
The City’s acceptance of the insurance certificates required under this Agreement does not relieve the CONTRACTOR from its obligation under this paragraph. The indemnification obligations of this section shall survive the termination of this agreement.
Any exceptions to this language may result in a proposal being deemed non-responsive.
CONTRACTOR/Subcontractor's responsibil ity for such defense and indemnity obligations shall survive the termination or completion of this agreement for the full period of time allowed by law.
The defense and indemnification obligations of this agreement are undertaken in addition to, and shall not in any way be limited by, th e insurance obligations contained in this agreement. If any section, subsection, sentence, clause or phrase of this indemnification is for any reason held to be invalid or unconsti tutional, such decision shall not affect the validity of the remaining portions of this indemnification.
5. STANDARD PLANS A ND SPECIFICATIONS. The performance of said work and the furnishing of said materials shall be executed in ac cordance with Section 8-1.04B of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27-1213, effective September 27, 2016, and the provisions of the issued project specifications.
The Director of Public Works will furnish CONTRACTOR a weekly statement showing the number of days charged to the contract for the preceding week, the number of days specified for completion of the contract, and the number of days remaining to complete the contract. CONTRACTOR will be allowed one (1) week in which to file a written protest setting forth in what respects said weekly statement is incorrect, otherwise the statement shall be deemed to have been accepted by CONTRACTOR as correct.
6. WORKING DAYS. This work shall be diligently prosecuted to completion before the expiration of 200 WORKING DAYS beginning on the tenth calendar day after the date shown on the Notice to Proceed. It is agreed by the parties to the contract that in case all the work called for under the c ontract in all parts and requirements, is not finished or completed within the number of days as set fo rth, damage will be sustained by the CITY, and that it is and will be impracticable and extremely difficult to ascertain the
EXHIBIT 2
Local Construction Contract – GEORGE REED, INC. – PROJECT NO. WT18005 (Updated 07/12/22) actual damage which CITY will sustain in the event of and by reason of such delay; and it is therefore agreed that CONTRACTOR will pay to CITY the sum of SIX THOUSAND EIGHT HUNDRED AND NO/100 DOLLARS ($6,800) per day for each and every calendar day's delay in finishing the work in e xcess of the number of days prescribed; and CONTRACTOR agrees to pay said liquidated damages as herein provided, and in case the same are not paid, agrees that CITY, may deduct the amount thereof from any monies due or that may become due CONTRACTOR under the contract.
It is further agreed that in case the work called for under the contract is not finished and completed in all parts and requirements within the number of days as specified, the CITY shall have the right to increas e the number of days or not, as may seem best to serve the interest of CITY, and if the CITY decid es to increase the said number of days, the CITY shall further have the right to char ge to CONTRACTOR, CONTRACTOR's heirs, assigns or sureties, and to deduct from the final payment for the work, all or any part, as may be deemed proper, the liquidated damages as specified or the actual cost of engineering, inspection, superintendence, and other ov erhead expenses which are directly chargeable to the contract, and which accrue during the period of such extension, whichever is greater, except the cost of fi nal surveys and preparation of final estimate shall not be included in such charges.
A working day shall not include, nor sha ll CONTRACTOR be assessed with liquidated damages nor the additional cost of engineeri ng and inspection during any delay beyond the time named for the completion of the work caused by acts of God or of the public enemy, acts of CITY, fire, fl oods, epidemics, quarantine restri ctions, strikes, and freight embargoes and subject to approval by the Direc tor of Public Works, inability to get materials ordered by CONTRACTOR or subcontractor due to such causes provided that CONTRACTOR shall notify the Director of Public Works in writing of the causes of delay within five (5) working days from the beginni ng of any such delay, and the Director shall ascertain the facts and the extent of the delay, and Director's findings of the facts thereon shall be final and conclusive.
If CONTRACTOR is delayed by reason of alterations made in these specifications, or by any act of the Director of Public Works or of the CITY, not contemplated by the contract, the time of completion shall be extended proportionately and CONTRACTOR shall be relieved during the period of such extension of any claim for liquidated damages, engineering or inspection charges or other penalties. CONTRACTOR shall have no claim for any other compensation for any such delay.
7. CONFORMANCE TO APPLICABLE LAWS. Contractor shall comply with all applicable Federal, State, and Municipal laws, rules and ordinances. Contractor shall not discriminate in the employme nt of persons or in the prov ision of services under this Contract on the basis of any legally protected classification, including race, color, national origin, ancestry, sex or religion of such person.
a. TITLE VI
EXHIBIT 2
Local Construction Contract – GEORGE REED, INC. – PROJECT NO. WT18005 (Updated 07/12/22) Title VI of the Civil Rights Act of 1964 requires that “no person in the United States shall, on the grounds of race, color, or national origin, be excluded from participation in, be denied the benefits o f, or be subjected to discrimination under any pr ogram or activity receiving federal financial assistance.” (42 USC Section 2000d)
http://www.dol.gov/oasam/regs/statutes/titlevi.htm.
The City of Stockton requires compliance with the requirements of Title VI in all of its programs and activities regardless of funding source.
b. DISCRIMINATION AND HARASSMENT POLICY
The City of Stockton has a Discriminat ion and Harassment Policy (Exhibit C). The purpose of this policy is to reaffirm the CITY’s commitment to demonstrating respect for all individuals by strictly prohibiting discrimination and harassment, including sexual harassment in the workplace, to define the types of behavior and conduct prohibited by this policy, and to set forth a procedure for reporting, investigat ing, and resolving complaints of discrimination and harassment in the workplace.
c. LABOR STANDARDS PROVISIO NS/CALIFORNIA LABOR CODE
The bidder shall understand that conditions set forth in Chapter 1, Part 7, Division 2 of the Calif ornia Labor Code shall be considered part of the contract agreement.
https://leginfo.legislature.ca.gov/faces/codes_displayText.xhtml?lawCode= LAB&division=2.&title=&part=7.&chapter=1.&article=2.
d. PREVAILING WAGE
CONTRACTOR and any subcontractor shall pay each employee engaged in the trade or occupation not less than the prevailing hourly wage rate. In accordance with the provis ions of Section 1770 of the Labor Code, the Director of Department of Industrial Relations of the State of California has determined the general prevailing rates of wages and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for in Section 1773. 1, apprenticeship or other training programs authorized by Section 3093 and similar purposes applicable to the work to be done. CONTRACTOR performing the work under this contract shall obtain a copy of t he wage rate determination and shall distribute copies to each subcontract or. As the wage determination for each craft reflects an expiration date, it shall be the prime CONTRACTOR and each subcontractor's responsibility to ensure that the prevailing wage rates of concern is current and paid to the employee.
EXHIBIT 2
Local Construction Contract – GEORGE REED, INC. – PROJECT NO. WT18005 (Updated 07/12/22) i. The CONTRACTOR performing the work shall be responsible for obtaining a copy of the State wage rate determination. State wage rates may be obtained at
http://www.dir.ca.gov/OPRL/pwd/Determinations/Northern/Northern.p df. The CONTRACTOR shall be responsible for posting said wage rates at a prominent location at the work site and shall maintain same in a good readable condition for the duration of the work.
ii. Should the CONTRACTOR choose to work on a Saturday, Sunday or on a holiday recognized by the Labor Unions, the CONTRACTOR shall reimburse the CITY the actual co st of engineering, inspection, superintendence, and or other overhead expenses which are directly chargeable to the contract. Should such work be undertaken at the request of the CITY, reimbursement will not be required. To conform strictly with the provisions of Division 2, Part 7, Chapter 1, Article 2, of the Labor Code of the State of Califo rnia. To forfeit as a penalty to CITY the sum of TWENTY-FIVE AND NO/100 DOLLARS ($25.00) for each laborer, worker, or mechanic employed by CONTRACTOR, or by any subcontractor under CONTRACTOR, in the execution of this contract, for each calendar day during which any laborer, worker, or mechanic is required or permitted to work more than eight (8) hours and who is not paid the general preva iling rate of per diem wages for holiday and overtime work in violat ion of the provisions of Sections 1770 to 1781 of the Labor Code of the State of California. That all sums forfeited under the provisions of the foregoing sections shall be deducted from the paym ents to be made under the terms of this contract.
iii. The CONTRACTOR to whom the cont ract is awarded shall ensure that the prime and each subcontractor will in accordance with Section 1776 of the Labor Code, maintain certified payroll records. A copy of said records shall be provided with each invoice to the Public Works Department, Attention Contract Comp liance Officer. It shall be the CONTRACTOR’S responsibility to obtain copies of the current prevailing wage rate determination for all subcontractors. Additionally, certified payroll records must be uploaded to the DIR website as required by labor code.
iv. The CONTRACTOR shall comply wit h the provisions established in Section 1777.5 of the Labor Code concerning the 1) certified approval by local joint apprenticeship committees for the employment and training of apprentices, and 2) contri bution of funds to administer and conduct apprenticeship programs, if applicable to the job.
e. LOCAL EMPLOYMENT ORDINANCE
EXHIBIT 2
Local Construction Contract – GEORGE REED, INC. – PROJECT NO. WT18005 (Updated 07/12/22) Pursuant to Stockton Municipal Code Section 3.68.095 the CONTRACTOR and all subcontractors shall make a good fa ith effort to employ at least 50 percent of the workforce on this proj ect from local residents, as measured by total labor work hours. Failure of any CONTRACTOR or subcontractor to comply with these requirements shall be deemed a material breach of the contract or subcontract. CONT RACTORS and subcontractors shall maintain records necessary for moni toring their compliance with section
3.68.095.
f. COMMUNITY WORKFORCE TRAINING AGREEMENT
Pursuant to the implementation of the Community Workforce Training Agreement (CWTA) adopted by the Cit y Council on July 26, 2016, the successful bidder shall be required to comply with the provisions of CWTA. For any project subject to this Agreement, the Local Hire, Priority Apprentice and Workforce Development Program requirements shall apply in lieu of the requirements of Stockton Municipal Code Section 3.68.095 and no separate compliance with Secti on 3.68.095 will be r equired of the Contractors/Employers working on the project (EXHIBIT D).
g. SANCTIONS
Deliverables must conform with all applicable federal, state, and local laws. Such conformity includes compliance with federal sanctions, and Contractor certifies that it has not and will not e ngage in prohibited transactions with sanctioned persons or entities.
CITY agrees:
8. COMPENSATION. To pay CONTRACTOR for the work herein
contemplated in the following manner: Progress payments will be made on or about the first day of each calendar month, in such sum as shall make the aggregate of payment up to such day equal to ninety-five percent (95%) of the proportional contract price, upon the basis of the progress certif icate of the Director of Public Works as to the amount of work done and the proportional amount of the contract price represented therefore; and all of the remaining part of t he contract price not as aforesai d paid, shall be paid at the expiration of thirty-five (35) days from the completion of said work of construction and the certification by the Director of Public Works of such completion.
9. SECURITIES. Pursuant to Section 22300 of the Public Contract Code, CONTRACTOR will be permitted, at its request and sole expense, to substitute securities for any monies withheld by the CITY to ensure performance under the contract. Said securities will be deposited either with the CITY or with a State or federally chartered bank as escrow agent. Securities eligible for this substitution are those listed in Section 16430 of the California Government Code or bank or savings and loan certificates of deposit.
EXHIBIT 2
Local Construction Contract – GEORGE REED, INC. – PROJECT NO. WT18005 (Updated 07/12/22) CONTRACTOR shall be the beneficial owner of any securities substituted for monies withheld and shall receive any interest thereon.
10. CHANGE ORDERS. CITY reserves the right to make such alterations, deviations, additions to or omissions from the plans and specifications, including the right to increase or decrease the quantity of any item or portion of the work, as may be deemed by the Engineer to be necessary or advisable and to require su ch extra work as may be determined by the Engineer to be required for the proper completion or construction of the whole work contemplated.
Any such changes will be set forth in a contract change order which will specify, in addition to the work done in connection with the change made, adjustment of contract time, if any, and the basis of compensation for such work . A contract change order will not become effective until approved by the City Manager and/or the City Council.
Processing of change orders shall be in accordance with Section 4-1. 05A of the City of Stockton Standard Specifications and Plans as adopted by Council on September 27, 2016, by Resolution No. 2016-09-27-1213, effective September 27, 2016, or as otherwise amended by Council. When the compensation for an item of work is subject to adjustment under the provisions of Standard Specif ications and Plans, Section 4-1.05A, CONTRACTOR shall, upon request, promptly furnish the Engineer with adequate detailed cost data for such item of work.
11. AUDITS. CITY reserves the right to peri odically audit all charges made by CONTRACTOR to CITY for services under the contract. Upon request, CONTRACTOR agrees to furnish CITY, or a designated repr esentative, with necessary information and assistance.
CONTRACTOR agrees that CITY or its delegate will have the right to review, obtain and copy all records pertaining to performance of the contract. CONTRACTOR agrees to provide CITY or its delegate with any rele vant information requested and shall permit CITY or its delegate access to its prem ises, upon reasonable notice, during normal business hours for the purpose of intervie wing employees and inspecting and copying such books, records, accounts, and other material that may be relevant to a matter under investigation for the purpos e of determining compliance with this requirement.
CONTRACTOR further agrees to maintain such records for a period of three (3) years after final payment under the contract.
12. WAIVER. It is expressly understood and agreed by and between the parties hereto that a waiver of any of the conditions of this contract shall not be considered a waiver of any of the other conditions thereof.
//
//
//
//
//
EXHIBIT 2
Local Construction Contract – GEORGE REED, INC. – PROJECT NO. WT18005 (Updated 07/12/22) It is further understood and agreed by and between the parties her eto that time is of the essence of this contract in all respects.
IN WITNESS WHEREOF, the parties hereto have hereunto affixed their hands and seals the day and year first above written.
A T T E S T : C I T Y :
ELIZA R. GARZA, CMC
CITY CLERK
B y :
By: HARRY BLACK
CITY MANAGER
APPROVED AS TO FORM & CONTENT:
LORI M. ASUNCION
OFFICE OF THE CITY ATTORNEY
B y :
GEORGE REED, INC.
B y :
DEPUTY CITY ATTORNEY
Tax Identification No.
EXHIBIT 2
EXHIBIT A
EXHIBIT 2
EXHIBIT A
EXHIBIT 2
EXHIBIT A
EXHIBIT 2
EXHIBIT A
EXHIBIT 2
EXHIBIT A
EXHIBIT 2
EXHIBIT A
EXHIBIT 2
EXHIBIT A
EXHIBIT 2
EXHIBIT A
EXHIBIT 2
EXHIBIT A
EXHIBIT 2
EXHIBIT A
EXHIBIT 2
REV 2022‐05‐17
Insurance Requirements for Construction Contracts
Contractor shall procure and maintain for the duration of the contract, and for 5 years thereafter, insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his agents, representatives, employees, or subcontractors.
MINIMUM SCOPE AND LIMIT OF INSURANCE
Coverage shall be at least as broad as:
1. Commercial General Liability (CGL): Insurance Services Office (ISO) Form CG 00 01 covering CGL on an “occurrence” basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $2,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit.
2. Automobile Liability: Insurance Services Office Form CA 0001 covering Code 1 (any auto), with limits no less than $2,000,000 per accident for bodily injury and property damage.
3. Workers’ Compensation insurance as required by the State of California, with Statutory Limits, and Employers’ Liability insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.
4. Surety Bonds as described below.
5. Professional Liability (if Design/Build), with limits no less than $2,000,000 per occurrence or claim, and $2,000,000 policy aggregate.
6. Contractors’ Pollution Legal Liability and/or Asbestos Legal Liability and/or Errors and Omissions (if project involves environmental hazards) with limits no less than $1,000,000 per occurrence or claim, and $2,000,000 policy aggregate.
If the contractor maintains broader coverage and/or higher limits than the minimums shown above, the City of Stockton requires and shall be entitled to the broader coverage and/or the higher limits maintained by the contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City of Stockton.
Self-Insured Retentions
EXHIBIT B
EXHIBIT 2
REV 2022‐05‐17
Self-insured retentions must be declared to and approved by the City of Stockton. The City of Stockton may require the Contractor to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention. The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the named insured or City of Stockton. The CGL and any policies, including Excess liability policies, may not be subject to a self-insured retention (SIR) or deductible that exceeds $25,000 unless approved in writing by City of Stockton. Any and all deductibles and SIRs shall be the sole responsibility of Contractor or subcontractor who procured such insurance and shall not apply to the Indemnified Additional Insured Parties. City of Stockton may deduct from any amounts otherwise due Contractor to fund the SIR/deductible. Policies shall NOT contain any self-insured retention (SIR) provision that limits the satisfaction of the SIR to the Named Insured.
The policy must also provide that Defense costs, including the Allocated Loss Adjustment Expenses, will satisfy the SIR or deductible. City of Stockton reserves the right to obtain a copy of any policies and endorsements for verification.
Other Insurance Provisions
The insurance policies are to contain, or be endorsed to contain, the following provisions:
1. The City of Stockton, its officers, officials, employees, and volunteers are to be covered as additional insureds on the CGL policy with respect to liability arising out of work or operations performed by or on behalf of the Contractor including materials, parts, or equipment furnished in connection with such work or operations and automobiles owned, leased, hired, or borrowed by or on behalf of the Contractor.
General liability coverage can be provided in the form of an endorsement to the Contractor’s insurance (at least as broad as ISO Form CG 20 10, CG 11 85 or both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 forms if later revisions used).
Additional insured Name of Organization shall read “City of Stockton, its officers, officials, employees, and volunteers.” Policy shall cover City of Stockton, its officers, officials, employees, and volunteers for all locations work is done under this contract.
2. For any claims related to this project, the Contractor’s insurance coverage shall be primary and non-contributory insurance coverage at least as broad as ISO CG 20 01 04 13 as respects the City of Stockton, its officers, officials, employees, and volunteers. Any insurance or self-insurance maintained by the City of Stockton, its officers, officials, employees, or volunteers shall be excess of the Contractor’s insurance and shall not contribute with it. This requirement shall also apply to any Excess or Umbrella liability policies. The City of Stockton does not accept endorsements limiting the Contractor’s insurance coverage to the sole negligence of the Named Insured.
EXHIBIT B
EXHIBIT 2
REV 2022‐05‐17
3. Each insurance policy required by this clause shall provide that coverage shall not be canceled, except with notice to the City of Stockton.
Builder’s Risk (Course of Construction) Insurance
Contractor may submit evidence of Builder’s Risk insurance in the form of Course of Construction coverage. Such coverage shall name the City of Stockton as a loss payee as their interest may appear.
If the project does not involve new or major reconstruction, at the option of the City of Stockton, an Installation Floater may be acceptable. For such projects, a Property Installation Floater shall be obtained that provides for the improvement, remodel, modification, alteration, conversion or adjustment to existing buildings, structures, processes, machinery and equipment. The Property Installation Floater shall provide property damage coverage for any building, structure, machinery or equipment damaged, impaired, broken, or destroyed during the performance of the Work, including during transit, installation, and testing at the City of Stockton’s site.
Claims Made Policies
If any coverage required is written on a claims-made coverage form:
1. The retroactive date must be shown, and this date must be before the execution date of the contract or the beginning of contract work.
2. Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of contract work.
3. If coverage is cancelled or non-renewed, and not replaced with another claims-made policy form with a retroactive date prior to the contract effective, or start of work date, the Contractor must purchase extended reporting period coverage for a minimum of five (5) years after completion of contract work.
4. A copy of the claims reporting requirements must be submitted to the City of Stockton for review.
5. If the services involve lead-based paint or asbestos identification/remediation, the Contractors Pollution Liability policy shall not contain lead-based paint or asbestos exclusions. If the services involve mold identification/remediation, the Contractors Pollution Liability policy shall not contain a mold exclusion, and the definition of Pollution shall include microbial matter, including mold.
Umbrella or Excess Policies
The Contractor may use Umbrella or Excess Policies to provide the liability limits as required in this agreement. This form of insurance will be acceptable provided that all of the Primary and Umbrella or Excess Policies shall provide all of the insurance
EXHIBIT B
EXHIBIT 2
REV 2022‐05‐17
coverages herein required, including, but not limited to, primary and non-contributory, additional insured, Self-Insured Retentions (SIRs), indemnity, and defense requirements. The Umbrella or Excess policies shall be provided on a true “following form” or broader coverage basis, with coverage at least as broad as provided on the underlying Commercial General Liability insurance. No insurance policies maintained by the Additional Insureds, whether primary or excess, and which also apply to a loss covered hereunder, shall be called upon to contribute to a loss until the Contractor’s primary and excess liability policies are exhausted.
Acceptability of Insurers
Insurance is to be placed with insurers authorized to conduct business in the state with a current A.M. Best rating of no less than A: VII, unless otherwise acceptable to the City of Stockton.
Waiver of Subrogation
Contractor hereby agrees to waive rights of subrogation which any insurer of Contractor may acquire from Contractor by virtue of the payment of any loss.
Contractor agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation. The Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of the City of Stockton for all work performed by the Contractor, its employees, agents and subcontractors.
Verification of Coverage
Contractor shall furnish the City of Stockton with original certificates and amendatory endorsements or copies of the applicable policy language effecting coverage required by this clause and a copy of the Declarations and Endorsements Pages of the CGL and any Excess policies listing all policy endorsements. All certificates and endorsements and copies of the Declarations & Endorsements pages are to be received and approved by the City of Stockton before work commences. However, failure to obtain the required documents prior to the work beginning shall not waive the Contractor’s obligation to provide them. The City of Stockton reserves the right to require complete, certified copies of all required insurance policies, including endorsements required by these specifications, at any time. City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances.
Subcontractors
Contractor shall require and verify that all subcontractors maintain insurance meeting all requirements stated herein, and Contractor shall ensure that City of Stockton is an additional insured on insurance required from subcontractors. For CGL coverage, subcontractors shall provide coverage with a form at least as broad as CG 20 38 04 13.
Duration of Coverage
EXHIBIT B
EXHIBIT 2
REV 2022‐05‐17
CGL & Excess liability policies for any construction related work, including, but not limited to, maintenance, service, or repair work, shall continue coverage for a minimum of 5 years for Completed Operations liability coverage. Such Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of the contract of work.
Surety Bonds
Contractor shall provide the following Surety Bonds:
1. Bid Bond
2. Performance Bond
3. Payment Bond
4. Maintenance Bond
The Payment Bond and the Performance Bond shall be in a sum equal to the contract price. If the Performance Bond provides for a one-year warranty a separate Maintenance Bond is not necessary. If the warranty period specified in the contract is for longer than one year a Maintenance Bond equal to 10% of the contract price is required. Bonds shall be duly executed by a responsible corporate surety, authorized to issue such bonds in the State of California and secured through an authorized agent with an office in California.
Special Risks or Circumstances
City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other circumstances.
Certificate Holder Address
The address for mailing certificates, endorsements and notices shall be:
City of Stockton
Its Officers, Officials, Employees and Volunteers
400 E Main Street, 3rd Floor – HR
Stockton, CA 95202
EXHIBIT B
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT D
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
24 BOND FOR FAITHFUL PERFORMANCE
KNOW ALL MEN BY THESE PRESENTS:
That we, GEORGE REED, INC., a STAT
E OF CA CORPORATION, as Principal
and ___, a corporation,
organized and existing under the laws of the State of and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, as obligee, in the just and full sum of NINE MILLION FOUR HUNDRED FORTY NI NE THOUSAND SIX HUNDRED TWENTY SIX AND NO/100 DOLLARS ($9,449,626.00), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to the said CITY, the said Principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.
The condition of the foregoing obligation is such that the above bounded Principal has simultaneously entered into a contract with the CITY, to do and perform the following work, to wit:
CALIFORNIA STREET ROAD DIET
(PROJECT NO. WT18005/ATPSB1L-5008(194))
NOW, THEREFORE, if the above bounde d Principal, CONTRACTOR, Company or
Corporation or its subcontract or, shall well and truly perform the work contracted to be done under said contract, then this obligation to be null and vo id; otherwise to remain in full force and effect.
No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract, or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY, and no forbearance on the part of the said CITY shall operate to relieve any Surety or Sureties from liability on this bond, and consent by said Surety is hereby given, and the said Surety hereby waives the EXHIBIT 2
25 provisions of Sections 2819 and 2845 of the Civil Code of the State of California.
SIGNED AND
SEALED on
APPROVED AS
TO SURETY: By:
P R I N C I P A L
S U R E T Y
APPROVED AS TO FORM & CONTENT:
JOHN M. LUEBBERKELORI M. ASUNCION
OFFICE OF THE CITY ATTORNEY
B y
:
A T T O R N E Y - I N - F A C T
B y
:
DEPUTY CITY ATTORNEY
EXHIBIT 2
1 BOND FOR LABOR AND MATERIAL
KNOW ALL MEN BY THESE PRESENTS:
That
we, GEORGE REED, INC., a STATE OF CA CORPORATION, as Principal and ___, a corporation,
organized and existing under the laws of the State of and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of Californi a, and unto any and all material suppliers, persons, companies, or corporations furnishing materials, provisions, provender or other supplies used in, upon, fo r or about the performance of the work contemplated to be executed or performed under the contract hereinafter mentioned, and all persons, companies, or corporations rent ing or hiring teams, or implements of machinery, for or contributing to said work and all persons who perform work or labor upon the same, and all persons who supply bot h work and materials, and whose claims have not been paid by the contractor, company or corporation in the just and full sum of
NINE MILLION FOUR HUNDRED FORTY NINE THOUSAND SIX HUNDRED TWENTY SIX AND NO/100 DOLLA RS ($9,449,626.00), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to said CITY and to said persons jointly and severally, the said principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.
The condition of the foregoing obligations is such that the above bounden Principal has simultaneously entered into a contract of even date herewith, wit h the CITY, to do and perform the following work, to-wit:
CALIFORNIA STREET ROAD DIET
(PROJECT NO. WT18005/ATPSB1L-5008(194))
NOW, THEREFORE, if the abov e bounden Principal, CO NTRACTOR, Company or Corporation or its subcontractor, fail to pay for all materials, provisions, provender, or other supplies, or teams, used in, upon, for or about the performance of the work EXHIBIT 2
2 contracted to be done, or for any work or la bor done thereon of any kind, the Surety on this bond will pa
y the same, in an amount not exceeding the sum specified in this bond, provided that any and all claims hereunder shall be filed and pr oceedings had in connection therewith as required by the provisions of Division 3, Part 4, Title 15, Chapter 5, Article 1 of the Civil Code of California, provided that in case suit is brought upon this bond, a reasonable attorney's fee shall be awarded by the Court to the prevailing party in said suit; said attorney's fee to be fixed as costs in said suit, and to be included in the judgment therein rendered.
No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract or in said plans or spec ifications agreed to between the said CONTRACTOR and the said CI TY and no forbearance on the part of the said CITY shall operate to relieve any sure ty or sureties from liability on this bond, and consent to make such alterations without further notice to or consent by any such surety is hereby given, and the said sureties hereby waive the provisions of Sections 2819 and 2845 of the Civil Code of the State of California.
S I G N E D A N D S E A L E D o n .
APPROVED AS
TO SURETY: By:
P R I N C I P A L
S U R E T Y
APPROVED AS TO FORM & CONTENT:
LORI M. ASUNCION
OFFICE OF THE CITY ATTORNEY
B y
:
A T T O R N E Y - I N - F A C T
B y
:
DEPUTY CITY ATTORNEY
EXHIBIT 2