City Council and Concurrent Authorities
December 5, 2023

EXHIBIT 2

CONSTRUCTION CONTRACT
This contract is made and ent ered into on , by and between TEROCONS INC. , a STATE OF CALIFORNIA CORPORATION, with a business address at 1160 BATTERY STREET, STE. 100, SAN FRANCISCO, CA 94111, hereinafter called "CONTRACTOR," and CITY OF STOCKTON, a municipal corporation, hereinafter called "CITY."
W I T N E S S E T H:

WHEREAS, plans and specifications for the construction of ADA CURB RAMP INSTALLATION (PROJECT NO. WD23004), hereinafter called “PROJECT,” were regularly adopted by Council Resolution No. , on
; and
WHEREAS, the contract for said work was regularly awarded to CONTRACTOR, by Council Resolution No. , on .

NOW, THEREFORE, in consideration of the promises and of the mutual covenants herein contained, the parties hereto expressly agree as follows:

CONTRACTOR agrees:

1. SCOPE OF SERVICES. To do the work and furnish all the labor, materials, tools, equipment, and insurance required for the construction of PROJECT in accordance with the plans and specific ations adopted on , by Council Resolution No. . The "contract documents," which include the bid documents, project plans, specifications, all letters of clarification, and the City of Stockton Standard Specifications and Plans, are incorporated into and made a part of this contract by this reference to the same extent as if fully set forth.

2. COMPENSATION. To do and perform the work contemplated hereby in a good and workmanlike manner and to furnish all labor, materials, tools, and equipment necessary therefore at the prices specified in Exhibit A, attached hereto and by reference made a part hereof, under the direction of and to the complete satisfaction of the Director of Public Works of the City of Stockton. Total compensation for services and reimbursement for costs shall not exceed $785,000.000, or as otherwise mutually agreed to in a Contract Change Order.

3. INSURANCE. CONTRACTOR shall not commence any work before obtaining, and shall maintain in force at all times during the duration and performance of this contract, the policies of insurance specified in Exhibit B, which is attached to this contract and incorporated by this reference, and as provided in the “contract documents” including Section 7-1.06 of the City of Stockton Standard S pecifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27-1213, effective September 27, 2016.

It shall be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be available to the Additional Insured.

Local Construction Contract – TEROCONS INC. – PROJECT NO. WD23004 (Updated 04/24/23)

Fur
thermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any i nsurance policy or proceeds available to the named Insured; whichever is greater.

The A
dditional Insured coverage under the CONTRACTOR’s policy shall be “primary and non-contributory” and will not seek contribution from the City of Stockton’s insurance or self-insurance and shall be at least as broad as ISO CG 20 01 04 13.

The l
imits of insurance required in this agreement may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess i nsurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis for the benefit of the City of Stockton (if agreed to in a written contract or agreement) before the City of Stockton’s own insurance or self - insurance shall be called upon to protect it as a named insured.

All s
elf-insured retentions (SIR) must be disclosed to the CITY’s Risk Management for approval and shall not reduce the limits of liability. Payment Bond in the amount of the self-insured retention (SIR) may be required.

Pol
icies containing any self-insured retention (SIR) provision shall provide or be endorsed to provide that the SIR may be satisfied by either the named insured or the CITY.

The CI
TY reserves the right to obtain a full certified copy of any i nsurance policy and endorsements.

Fai
lure to exercise this right shall not constitute a waiver of right to exercise later.

CONT
RACTOR shall maintain insurance as required by this contract to the fullest amount allowed by law and shall maintain insurance for a minimum of five years following the completion of this project. In the event contractor fails to obtain or maintain completed operations coverage as required by this agreement, the City at its sole discretion may purchase the coverage required and the cost will be paid by contractor.

CONT
RACTOR agrees to include with all Subcontractors in their subcontract the same requirements and provisions of this agreement including the indemnity and insurance requirements to the extent they apply to the scope of the Subcontractor’s work.

Subcontractors hired by CONTRACTOR agree to be bound to CONTRACTOR and the CITY in the same manner and to the same extent as CONTRACTOR is bound to the CITY under the Contract Documents. Subcontractor further agrees to include these same provisions with any Sub-subcontractor. A copy of the CITY Contract Document Indemnity and Insurance provisions will be furnished to the Subcontractor upon request. The General CONTRACTOR shall require all sub-contractors to provide a valid certificate of insurance and the required endorsements included in the agreement prior to commencement of any work and contractor will provide proof of compliance to the City.

EXHIBIT 2

4. INDEMNITY AND HOLD HARMLESS. With the exception that this section shall in no event be construed to require indemnification by Contractor to a greater extent than permitted under the public policy of the State of California, Contractor shall indemnify, protect, defend with counsel approved by City and at Contractor’s sole cost and expense, and hold harmless the City of Stockton, its officers, officials, employees, and volunteers from and against any and all claims, causes of action, liabilities, judgments, awards, losses, liens, claims, stop notices, damages, expenses, and costs (including without limitation attorneys’ fees, expert and consultant fees, and other expenses of litigation) of every nature, including, but not limited to, death or injury to persons, or damage to property, which arise out of or are in any way connected with the work performed, materials furnished, or services provided under this Agreement, or from any violation of any federal, S tate, or municipal law or ordinance, or City Policy, by Contractor or Contractor’s officers, agents, employees, volunteers or subcontractors. Contractor shall not be obligated to indemnify or defend City for claims finally determined by a court of law or arbitrator to arise from the active negligence or willful misconduct of the City. It is the intent of the Parties that this indemnity obligation is at least as broad as is permitted under California law. To the extent California Civil Code sections 2782, et seq., limit the defense or indemnity obligations of Contractor to City, the intent hereunder is to provide the maximum defense and indemnity obligations allowed by Contractor under the law.

The indemnity set forth in this section shall not be limited by insurance requirements or by any other provision of this Agreement.

With ex
ception that this section shall in no event be construed to require indemnification, including the duty to defend, by Contractor to a greater extent than permitted under the public policy of the State of California, the parties agree that Contractor’s duty to defend City is immediate and arises upon the filing of any claim against the City for damages which arise out of or are in any way connected with the work performed, materials furnished, or services provided under this Agreement by Contractor or Contractor’s officers, agents, employees, volunteers or subcontractors. Contractor’s duties and obligations to defend the City shall apply regardless of whether or not the issue of the City’s liability, breach of this Agreement, or other obligation or fault has been determined.

Contractor shall be immediately obligated to pay for City’s defense costs of the claim, including, but not limited to, court costs, attorney’s fees and costs, expert consultant and witness fees and costs, other witness fees, document reproduction costs, arbitration fees, and, if after final judgment an appeal is pursued, all of such costs for the appeal.

At the conclusion of the claim, if there is any determination or finding of sole ac tive negligence or willful misconduct on the part of the City, City will then reimburse Contractor for amounts paid in excess of Contractor’s proportionate share of responsibility for the damages within 30 days after Contractor provides City with copies of all bills and expenses incurred in the defense of the claim(s). It is agreed between the parties that this reimbursement provision assures Contractor is not obligated to defend or indemnify City in an amount greater than provided for under California law , including, without limitation, California Civil Code sections 2782, 2782.6, and 2782.8.

With the ex
ception that this section shall in no event be construed to require indemnification by Contractor to a greater extent than permitted under the public policy of the State of California, and in addition to the other indemnity obligations in this Agreement, Contractor shall indemnify, defend, and hold harmless the City of Stockton,

EXHIBIT 2

its officers, officials, employees , and volunteers from and against all claims, losses, expenses, and costs including, but not limited to, attorneys’ fees, arising out of any claim brought against the City by an employee, office, agent, or volunteer of Contractor, regardless of whether such claim may be covered by any applicable workers compensation insurance. Contractor’s indemnification obligation is not limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for the Contractor under workers’ compensation acts, disability acts, or other employee benefit acts.

The C
ity’s acceptance of the insurance certificates required under this Agreement does not relieve the CONTRACTOR from its obligation under this paragraph. The indemnification obligations of this section shall survive the termination of this agreement.

Any exceptions to this language may result in a proposal being deemed non-responsive.

CONTRACTOR/Subcontractor's responsibility for such defense and indemnity obligations shall survive the termination or completion of this agreement for the full period of time allowed by law.

The def
ense and indemnification obligations of this agreement are undertaken in addition to, and shall not in any way be limited by, the insurance obligations contained in this agreement. If any section, subsection, sentence, clause or phrase of this indemnification is for any reason held to be invalid or unconstitutional, such decision shall not affect the validity of the remaining portions of this indemnification.

5. S
TANDARD PLANS AND SPECIFICATIONS. The performance of said work and the furnishing of said materials shall be executed in accordance with Section 8-1.04B of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, b y Council Resolution No. 2016- 09-27-1213, effective September 27, 2016, and the provisions of the issued project specifications.

The D
irector of Public Works will furnish CONTRACTOR a weekly statement showing the number of days charged to the contract for the preceding week, the number of days specified for completion of the contract, and the number of days remaining to complete the contract. CONTRACTOR will be allowed one (1) week in which to file a written protest setting forth in what respects said weekly statement is incorrect, otherwise the statement shall be deemed to have been accepted by CONTRACTOR as correct.

6. W
ORKING DAYS. This work shall be diligently prosecuted to completion before the expiration of 65 WORKING DAYS beginning on the tenth calendar day after the date shown on the Notice to Proceed. It is agreed by the parties to the contract that in case all the work called for under the contract in all parts and requirements, is not finished or completed within the number of days as set forth, damage will be sustained by the CITY, and that it is and will be impracticable and extremely difficult to ascertain the actual damage which CITY will sustain in the event of and by reason of such delay; and it is therefore agreed that CONTRACTOR will pay to CITY the sum of ONE THOUSAND EIGHT HUNDRED AND NO/100 DOLLARS ($ 1,800.00) per day for each and every calendar day's delay in finishing the work in excess of the number of days prescribed; and CONTRACTOR agrees to pay said liquidated damages as herein provided, and in EXHIBIT 2

case the same are not paid, agrees that CITY, may deduct the amount thereof from any monies due or that may become due CONTRACTOR under the contract.

It
is further agreed that in case the work called for under the contract is not finished and completed in all parts and requirements within the number of days as specified, the CITY shall have the right to increase the number of days or not, as may seem best to serve the interest of CITY, and if the CITY decides to increase the said number of days, the CITY shall further have the right to charge to CONTRACTOR, CONTRACTOR's heirs, assigns or sureties, and to deduct from the final payment for the work, all or any part, as may be deemed proper, the liquidated damages as specified or the actual cost of engineering, inspection, superintendence, and other overhead expenses which are directly chargeable to the contract, and which accrue during the period of such extension, whichever is greater, except the cost of final surveys and preparation of final estimate shall not be included in such charges.

A w
orking day shall not include, nor shall CONTRACTOR be assessed with liquidated damages nor the additional cost of engineering and inspection during any delay beyond the time named for the completion of the work caused by acts of God or of the public enemy, acts of CITY, fire, floods, epidemics, quarantine restrictions, strikes, and freight embargoes and subject to approval by the Director of Public Works , inability to get materials ordered by CONTRACTOR or subcontractor due to such causes provided that CONTRACTOR shall notify the Director of Public Works in writing of the causes of delay within five (5) working days from the beginning of any such delay, and the Director shall ascertain the facts and the extent of the delay, and Director's findings of the facts thereon shall be final and conclusive.

If
CONTRACTOR is delayed by reason of alterations made in these specifications, or by any act of the Director of Public Works or of the CITY, not contemplated by the contract, the time of completion shall be extended proportionately and CONTRACTOR shall be relieved during the period of such extension of any claim for liquidated damages, engineering or inspection charges or other penalties. CONTRACTOR shall have no claim for any other compensation for any such delay.

7. CO
NFORMANCE TO APPLICABLE LAWS. Contractor shall comply with all applicable Federal, State, and Municipal laws, rules, and ordinances. Contractor shall not discriminate in the employment of persons or in the provision of services under this Contract on the basis of any legally protected classification, including race, color, national origin, ancestry, sex or religion of such person.
a. TITL
E VI
Ti
tle VI of the Civil Rights Act of 1964 requires that “no person in the United States shall, on the grounds of race, color, or national origin, be excluded from participation in, be denied the benefits of, or be subjected to discrimination under any program or activity receiving federal financial assistance.” (42 USC Section 2000d)
http://www.dol.gov/oasam/regs/statutes/titlevi.htm.

EXHIBIT 2

The City of Stockton requires compliance with the requirements of Title VI in all of its programs and activities regardless of funding source. b. DIS

CRIMINATION AND HARASSMENT POLICY
The C
ity of Stockton has a Discrimination and Harassment Policy ( Exhibit C). The purpose of this policy is to reaffirm the CITY’s commitment to demonstrating respect for all individuals by strictly prohibiting discrimination and harassment, including sexual harassment in the workplace, to define the types of behavior and conduct prohibited by this policy, and to set forth a procedure for reporting, investigating, and resolving complaints of discrimination and harassment in the workplace.
c. LABO

R STANDARDS PROVISIONS/CALIFORNIA LABOR CODE
The bi
dder shall understand that conditions set forth in Chapter 1, Part 7, Division 2 of the California Labor Code shall be considered part of the contract agreement.
https://leginfo.legislature.ca.gov/faces/codes_displayText.xhtml?lawCode= LAB&division=2.&title=&part=7.&chapter=1.&article=2.
d. PREVAI

LING WAGE
CO
NTRACTOR and any subcontractor shall pay each employee engaged in the trade or occupation not less than the prevailing hourly wage rate. In accordance with the provisions of Section 1770 of the Labor Code, the Director of Department of Industrial Relations of the State of California has determined the general prevailing wage and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for in Section 1773.1, apprenticeship or other training programs authorized by Section 3093 and similar purposes applicable to the work to be done. CONTRACTOR performing the work under this contract shall obtain a copy of the wage rate determination and shall distribute copies to each subcontractor. As the wage determination for each craft reflects an expiration date, it shall be the prime CONTRACTOR and each subcontractor's responsibility to e nsure that the prevailing wage rates of concern is current and paid to the employee.
i. T
he CONTRACTOR performing the work shall be responsible for obtaining a copy of the State wage rate determination. State wage rates may be obtained at
http://www.dir.ca.gov/OPRL/pwd/Determinations/Northern/Northern.pd f. The CONTRACTOR shall be responsible for posting said wage rates at a prominent location at the work site and shall maintain same in a good readable condition for the duration of the work.
ii. S
hould the CONTRACTOR choose to work on a Saturday, Sunday or on a holiday recognized by the Labor Unions, the CONTRACTOR shall EXHIBIT 2

reimburse the CITY the actual cost of engineering, inspection, superintendence, and or other overhead expenses which are directly chargeable to the contract. Should such work be undertaken at the request of the CITY, reimbursement will not be required. To conform strictly with the provisions of Division 2, Part 7, Chapter 1, Article 2, of the Labor Code of the State of California. To forfeit as a penalty to CITY the sum of TWENTY -FIVE AND NO/100 DOLLARS ($25.00) for each laborer, worker, or mechanic employed by CONTRACTOR, or by any subcontractor under CONTRACTOR, in the execution of this contract, for each calendar day during which any laborer, worker, or mechanic is required or permitted to work more than eight (8) hours and who is not paid the general prevailing rate of per diem wages for holiday and overtime work in violation of the provisions of Sections 1770 to 1781 of the Labor Code of the State of California. That all sums forfeited under the provisions of the foregoing sections shall be deducted from the payments to be made under the terms of this contract.
iii. T
he CONTRACTOR to whom the contract is awarded shall ensure that the prime and each subcontractor will in accordance with Section 1776 of the Labor Code, maintain certified payroll records. A copy of said records shall be provided with each invoice to the Public Works Department, Attention Contract Complianc e Officer. It shall be the CONTRACTOR’S responsibility to obtain copies of the current prevailing wage rate determination for all subcontractors. Additionally, certified payroll records must be uploaded to the DIR website as required by labor code.
iv. The C
ONTRACTOR shall comply with the provisions established in Section 1777.5 of the Labor Code concerning the 1) certified approval by local joint apprenticeship committees for the employment and training of apprentices, and 2) contribution of funds to administer and conduct apprenticeship programs, if applicable to the job. e. LO

CAL EMPLOYMENT ORDINANCE
Pur
suant to Stockton Municipal Code Section 3.68.095 the CONTRACTOR and all subcontractors shall make a good faith effort to employ at least 50 percent of the workforce on this project from local residents, as measured by total labor work hours. Failure of any CONTRACTOR or subcontractor to comply with these requirements shall be deemed a material breach of the contract or subcontract. CONTRACTORS and subcontractors shall maintain records necessary for monitoring their compliance with section

3.68.095.
f. SA

NCTIONS
Del
iverables must conform with all applicable federal, state, and local EXHIBIT 2

laws. Such conformity includes compliance with federal sanctions, and Contractor certifies that it has not and will not engage in prohibited transactions with sanctioned persons or entities.

CI
TY agrees:

8. CO
MPENSATION. To pay CONTRACTOR for the work herein
contemplated in the following manner: Progress payments will be made on or about the first day of each calendar month, in such sum as shall make the aggregate of payment up to such day equal to ninety-five percent (95%) of the proportional contract price, upon the basis of the progress certificate of the Director of Public Works as to the amount of work done and the proportional amount of the contract price represented therefor e; and all of the remaining part of the contract price not as aforesaid paid, shall be paid at the expiration of thirty-five (35) days from the completion of said work of construction and the certification by the Director of Public Works of such completion.

9. SEC
URITIES. Pursuant to Section 22300 of the Public Contract Code, CONTRACTOR will be permitted, at its request and sole expense, to substitute securities for any monies withheld by the CITY to ensure performance under the contract. Said securities will be deposited either with the CITY or with a State or federally chartered bank as escrow agent. Securities eligible for this substitution are those listed in Section 16430 of the California Government Code or bank or savings and loan certificates of depos it.

CONTRACTOR shall be the beneficial owner of any securities substituted for monies withheld and shall receive any interest thereon.

10. CHANG
E ORDERS . CITY reserves the right to make such alterations, deviations, additions to or omissions from the plans and specifications, including the right to increase or decrease the quantity of any item or portion of the work, as may be deemed by the Engineer to be necessary or advisable and to require such extra work as may be determined by the Engineer to be required for the proper completion or construction of the whole work contemplated.

Any
such changes will be set forth in a contract change order which will specify, in addition to the work done in connection with the change made, adjustment of contract time, if any, and the basis of compensation for such work. A contract change order wi ll not become effective until approved by the City Manager and/or the City Council.

Pr
ocessing of change orders shall be in accordance with Section 4- 1.05A of the City of Stockton Standard Specifications and Plans as adopted by Council on September 27, 2016, by Resolution No. 2016-09-27-1213, effective September 27, 2016, or as otherwise amended by Council. When the compensation for an item of work is subject to adjustment under the provisions of Standard Specifications and Plans, Section 4- 1.05A, CONTRACTOR shall, upon request, promptly furnish the Engineer with adequate detailed cost data for such item of work.

11. AUDI
TS. CITY reserves the right to periodically audit all charges made by CONTRACTOR to CITY for services under the contract. Upon request, CONTRACTOR EXHIBIT 2

agrees to furnish CITY, or a designated representative, with necessary information and assistance.

CONTRACTOR agrees that CITY or its delegate will have the right to review, obtain and copy all records pertaining to performance of the contract. CONTRACTOR agrees to provide CITY or its delegate with any relevant information requested and shall permit CITY or its delegate access to its premises, upon reasonable notice, during normal business hours for the purpose of interviewing employees and inspecting and copying such books, records, accounts, and other material that may be relevant to a matter under investigation for the purpose of determining compliance with this requirement.

CONTRACTOR further agrees to maintain such records for a period of three (3) years after final payment under the contract.

12. WAIVER. It is expressly understood and agreed by and between the parties hereto that a waiver of any of the conditions of this contract shall not be considered a waiver of any of the other conditions thereof.

It is further understood and agreed by and between the parties hereto that time is of the essence of this contract in all respects.

IN WITNESS WHEREOF, the parties hereto have hereunto affixed their hands and seals the day and year first above written.

ATTEST:

ELIZA R. GARZA

CITY CLERK
By: ____________ _
APPROVED AS TO FORM & CONTENT:

LORI M. ASUNCION

OFFICE OF THE CITY ATTORNEY
By:-------------

DEPUTY CITY ATTORNEY
CITY:

By: ____________ _

HARRY BLACK

CITY MANAGER
.. jk)
By: ___ j_'IPr _________ _
TEROCONS, INC.
qg,-�/4{Cf!Cf
Tax Identification No.

Local Construction Contract -TEROCONS INC. -PROJECT NO. WD23004 (Updated 04/24/23)

EXHIBIT 2

ADA CURB RAMP INSTALLATION
PROJECT NO. WD23004C

BID DING SCHEDULE
Each bidder shall bid each item, including all alternate bid(s). Failure to bid an item shall be just cause for considering the bid as non-responsive. Line-item costs should include all Contractor's overhead and profit and indirect costs. Bids not presented on City forms shall be cause for considering the bid as non-responsive.

Item Description Unit Quantity Unit price Total Price
1 2
3 4
5 6
7 8
Mobilization 1 LS
Traffic Control 1 LS
Curb-Ramp Installation Per COS
Standard Detail R-64 (All Work 12 EA
Complete In-Place)
Curb-Ramp Installation Per COS
Standard Detail R-65 (All Work 30 EA
Complete In-Place)
Curb-Ramp Installation Per COS
Standard Detail R-66 (All Work 8 EA
Complete In-Place)
Curb-Ramp Installation Per COS Detail
'Wheelchair Ramp Modified A' (All 17 EA
Work Complete In-Place)
Curb-Ramp Installation Per COS Detail
'Wheelchair Ramp Modified C' (All 1 EA
Work Complete In-Place)
Additional Concrete Sidewalk Removal
and Replacement (All Work Complete 2670 SF
In-Place)
Additional Vertical Curb and Gutter
9 Removal and Replacement (All Work 140 LF
Complete In-Place)
Additional Rolled Curb and Gutter
1 0 Removal and Replacement (All Work 220
Complete In-Place)
LF

TOTAL BID
40,000.00 $40,000.00
15,240.00 $15,240.00
9,250.00 $111,000.00
9,250.00 $277,500.00
9,250.00 $74,000.00
10,100.00 $171,700.00
10,000.00 $10,000.00

28.00 $74,760.00
'ln nn cl' A f)f\f\ f\f\

30.00 $6,600.00
$ 785,000.00 --------
BIDDER'S NAME __ T_e_r_o_c _o_ns_ln_ c_. ___ _
Bid Forms Last Revised 12/31/20
i
i=
F-
I=
EXHIBIT 2

EXHIBIT A
8/24/23, 12:05AM cadir.my.salesforce-sites.com/ContractorSearch/PrintRegDetails Contractor Information
Legal Entity Name
Terocons Inc.

Legal Entity Type
Corporation
Status
Active
Registration Number
PW-LR-1000978603
Registration effective date
7/1/2023
Registration expiration date
6/30/2024
Mailing Address
1444 Meridian st Manteca 95337 CA United States of A. ..

Physical Address
1160 Battery Street East, Suite 100 San francisco 94111 ...

Email Address
Trade Name/OBA
License Number(s)
CSLB:1097207
:Legal Entity Information
1 Corporation Number:

Federal Employment Identification Number:

President Name:

Marco Antonio Gutierrez Jimenez
Vice President Name:

Treasurer Name:

Secretary Name:

Marco Antonio Gutierrez Jimenez
CEO Name:

Marco Antonio Gutierrez Jimenez
Agent of Service Name:

MARCO ANTONIO GUTIERREZ JIMENEZ
, Agent of Service Mailing Address:
1228 lincoln st Fairfield 94533 CA United States of America Workers Compensation
-,--oo you lease employees No
through Professional
hltps://cadir.my.salesforce-sites.com/ContractorSearch/PrintRegDetails Registration History
Effective Date
9/30/2022
7/1/2023
Expiration Date
6/30/2023
6/30/2024
1/2
EXHIBIT 2

EXHIBIT A
8/24/23, 12:05 AM
Employer Organization
(PEO)?:

Please provide your
current workers
compensation insurance
information below:

PEO
PEO InformationName
Insured by Carrier
PEO
Phone
cadir.my.sale sforce-sites.com/ContractorSearch/PrintRegDetails PEO
Email
Policy Holder Name:Terocons Inclnsurance Carrier:

Clear Spring Property and Casualty CompanyPolicy Number:CWC01256100Inception date:
10/27 /2022Expiration Date:10/27 /2023
https://cadir.my.salesforce-sites.com/ContractorSearch/PrintRegDetails 2/2 EXHIBIT 2

EXHIBIT A
Exhibit B:

Insurance Requirements
(ADA Curb Ramp Installation, Project No. WD23004C)
Contract
or shall procure and maintain for the duration of the contract, and for 5 years thereafter, insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his agents, representatives, employees, or subcontractors.

MINIMUM SCOPE A

ND LIMIT OF INSURANCE
Coverage
shall be at least as broad as:

1. Commerc
ial General Liability (CGL): Insurance Services Office (ISO) Form CG 00 01 covering CGL on an “occurrence” basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $2,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit.

2. Automobile Lia
bility: Insurance Services Office Form CA 0001 covering Code 1 (any auto), with limits no less than $2,000,000 per accident for bodily injury and property damage.

3. Workers’ Co
mpensation insurance as required by the State of California, with Statutory Limits, and Employers’ Liability insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.

4. Surety Bon
ds as described below.

If the co
ntractor maintains broader coverage and/or higher limits than the minimums shown above, the City of Stockton requires and shall be entitled to the broader coverage and/or the higher limits maintained by the contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City of Stockton.

Self-Insured
Retentions
Self-ins
ured retentions must be declared to and approved by the City of Stockton. The City of Stockton may require the Contractor to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention. The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by EXHIBIT 2

EXHIBIT B
either the named insured or City of Stockton. The CGL and any policies, including Excess liability policies, may not be subject to a self-insured retention (SIR) or deductible that exceeds $25,000 unless approved in writing by City of Stockton. Any and all deductibles and SIRs shall be the sole responsibility of Contractor or subcontractor who procured such insurance and shall not apply to the Indemnified Additional Insured Parties. City of Stockton may deduct from any amounts otherwise due Contractor to fund the SIR/deductible. Policies shall NOT contain any self-insured retention (SIR) provision that limits the satisfaction of the SIR to the Named Insured.

The policy must also provide that Defense costs, including the Allocated Loss Adjustment Expenses, will satisfy the SIR or deductible. City of Stockton reserves the right to obtain a copy of any policies and endorsements for verification.

Other
Insurance Provisions
The
insurance policies are to contain, or be endorsed to contain, the following provisions:

1. The Ci
ty of Stockton, its officers, officials, employees, and volunteers are to be covered as additional insureds on the CGL policy with respect to liability arising out of work or operations performed by or on behalf of the Contractor including materials, parts, or equipment furnished in connection with such work or operations and automobiles owned, leased, hired, or borrowed by or on behalf of the Contractor.

General liability coverage can be provided in the form of an endorsement to the Contractor’s insurance (at least as broad as ISO Form CG 20 10 11 85 or both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 forms if later revisions used).

Additional insured Name of Organization shall read “City of Stockton, its officers, officials, employees, and volunteers.” Policy shall cover City of Stockton, its officers, officials, employees, and volunteers for all locations work is done under this contract.

2. F
or any claims related to this project, the Contractor’s insurance coverage shall be primary and non-contributory insurance coverage at least as broad as ISO CG 20 01 04 13 as respects the City of Stockton, its officers, officials, employees, and volunteers. Any insurance or self-insurance maintained by the City of Stockton, its officers, officials, employees, or volunteers shall be excess of the Contractor’s insurance and shall not contribute with it. This requirement shall also apply to any Excess or Umbrella liability policies. The City of Stockton does not accept endorsements limiting the Contractor’s insurance coverage to the sole negligence of the Named Insured.

3. E
ach insurance policy required by this clause shall provide that coverage shall not be canceled, except with notice to the City of Stockton.

Claims Made Policies (Professional & Pollution only)
EXHIBIT 2

EXHIBIT B
If any coverage required is written on a claims-made coverage form:

1. Th
e retroactive date must be shown, and this date must be before the execution date of the contract or the beginning of contract work.

2. I
nsurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of contract work.

3. If
coverage is cancelled or non-renewed, and not replaced with another claims-made policy form with a retroactive date prior to the contract effective, or start of work date, the Contractor must purchase extended reporting period coverage for a minimum of five (5) years after completion of contract work.

4. A
copy of the claims reporting requirements must be submitted to the City of Stockton for review.

5. I
f the services involve lead-based paint or asbestos identification/remediation, the Contractors Pollution Liability policy shall not contain lead-based paint or asbestos exclusions. If the services involve mold identification/remediation, the Contractors Pollution Liability policy shall not contain a mold exclusion, and the definition of Pollution shall include microbial matter, including mold.

Umbrella or Excess Policies
The Contractor may use Umbrella or Excess Policies to provide the liability limits as required in this agreement. This form of insurance will be acceptable provided that all of the Primary and Umbrella or Excess Policies shall provide all of the insurance coverages herein required, including, but not limited to, primary and non-contributory, additional insured, Self-Insured Retentions (SIRs), indemnity, and defense requirements. The Umbrella or Excess policies shall be provided on a true “following form” or broader coverage basis, with coverage at least as broad as provided on the underlying Commercial General Liability insurance. No insurance policies maintained by the Additional Insureds, whether primary or excess, and which also apply to a loss covered hereunder, shall be called upon to contribute to a loss until the Contractor’s primary and excess liability policies are exhausted.

Acceptability of Insurers
Insurance is to be placed with insurers authorized to conduct business in the state with a current A.M. Best rating of no less than A: VII, unless otherwise acceptable to the City of Stockton.

Waiver of Subrogation
Contractor hereby agrees to waive rights of subrogation which any insurer of Contractor may acquire from Contractor by virtue of the payment of any loss.

Contractor agrees to obtain any endorsement that may be necessary to affect this EXHIBIT 2

EXHIBIT B
waiver of subrogation. The Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of the City of Stockton for all work performed by the Contractor, its employees, agents and subcontractors.

Verification of Coverage
Contractor shall furnish the City of Stockton with original certificates and amendatory endorsements or copies of the applicable policy language effecting coverage required by this clause and a copy of the Declarations and Endorsements Pages of the CGL and any Excess policies listing all policy endorsements. All certificates and endorsements and copies of the Declarations & Endorsements pages are to be received and approved by the City of Stockton before work commences. However, failure to obtain the required documents prior to the work beginning shall not waive the Contractor’s obligation to provide them. The City of Stockton reserves the right to require complete, certified copies of all required insurance policies, including endorsements required by these specifications, at any time. City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances.

Subcontractors
Contractor shall require and verify that all subcontractors maintain insurance meeting all requirements stated herein, and Contractor shall ensure that City of Stockton is an additional insured on insurance required from subcontractors. For CGL coverage, subcontractors shall provide coverage with a form at least as broad as CG 20 38 04 13.

Duration of Coverage
CGL & Excess liability policies for any construction related work, including, but not limited to, maintenance, service, or repair work, shall continue coverage for a minimum of 5 years for Completed Operations liability coverage. Such Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of the contract of work .

Surety Bonds
Contractor shall provide the following Surety Bonds:

1. Bi
d Bond

2. Pe
rformance Bond

3. P
ayment Bond

4. M
aintenance Bond
The
Payment Bond and the Performance Bond shall be in a sum equal to the contract price. If the Performance Bond provides for a one-year warranty a separate EXHIBIT 2

EXHIBIT B
Maintenance Bond is not necessary. If the warranty period specified in the contract is for longer than one year a Maintenance Bond equal to 10% of the contract price is required. Bonds shall be duly executed by a responsible corporate surety, authorized to issue such bonds in the State of California and secured through an authorized agent with an office in California.

Special Risks or Circumstances
City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other circumstances.

Certi
ficate Holder Address
The
address for mailing certificates, endorsements and notices shall be:

City
of Stockton
Its Officers, Officials, Employees and Volunteers
400 E Main Street, 3rd Floor – HR
Stockton, CA 95202
EXHIBIT 2

EXHIBIT B
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 1 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 I. PURPOSE
The purpose of this policy is to reaffirm the City's commitment to demonstrating respect for all individuals by strictly prohibiting discrimination and harassment, including sexual harassment in the workplace. This policy defines prohibited behavior and conduct, and sets forth a procedure for reporting, investigating and resolving complaints of discrimination, harassment, in the workplace, including retaliation and hostile work environment.

II. POLICY
A. The City of Stockton prohibits any form of discrimination and/or harassment of any person based on race, religious creed, color, national origin, ancestry, military and veterans status, physical or mental disability, medical condition, genetic characteristics or information, denial of family and medical care leave, marital status, sexual orientation, sex (including gender, gender identity, gender expression, transgender, pregnancy, childbirth and breastfeeding), political affiliation, age (40 and older), concerted labor activity, or any other category or attribute consistent with state or federal law.

All such discrimination and harassment is unlawful and shall not be tolerated. In addition, under the federal Affordable Care Act (ACA), the City of Stockton prohibits discrimination and/or harassment, or retaliation against an employee who obtains coverage, receives a tax credit or subsidy through the Health Care "Market Place" or "Exchange."
B. It is an unlawful employment practice to discriminate against or to harass an unpaid intern or volunteer on the basis of any legally protected classification unless an exception applies, such as a bona fide occupational qualification.

C. The City will neither tolerate nor condone discrimination and/or harassment of employees by managers, supervisors, co-workers, or non-employees with whom City employees have a business service, or professional relationship.

D. All City employees and non-employees share a responsibility to assist in EXHIBIT 2

EXHIBIT C
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 2 of 14
DISCRIMINATION AND Effective Date: Revised From: HARASSMENT POLICY 7/27/09 5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 maintaining an employment environment free of discrimination and harassment. This policy applies to all aspects of City employment, including, but not limited to, hiring, reassignment, placement, promotion, employment action, disciplinary action, layoff, reemployment, transfer, leave of absence, compensation and benefits, training; or other terms of treatment of that person in an unpaid internship, or another limited duration program to provide unpaid work experience for that person, or the harassment of an unpaid intern or volunteer.

E. All allegations of discrimination and/or harassment shall be investigated immediately by the City, in accordance with this policy. If it is determined that any prohibited activity has occurred, remedial action shall be taken. Such action may include discipline up to and including discharge. In addition, under applicable law, individual supervisors and employees may be subject to personal liability and/or punitive damages in any litigation arising as a result of such conduct.

F. All new hires shall attend harassment awareness training, and supervisors and managers shall attend harassment awareness and prevention training for supervisors every two years.

G. The City of Stockton prohibits retaliation against any employee or non­ employee by another employee, non-employee, supervisor, or manager for reporting, filing, testifying, assisting or participating in any manner in any investigation, proceeding, or hearing conducted by the employer or a federal or state enforcement agency.

H. This policy applies to all officials, employees, volunteers, unpaid interns, agents, or contractors of the City.

I. This policy shall be administered by the Director of Human Resources.

EXHIBIT 2

EXHIBIT C
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 3 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment m the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 Ill. DEFINITION AND EXAMPLES OF DISCRIMINATION AND HARASSMENT A. "Discrimination," as used in this policy, is any action, behavior, practice, or process that is intended to deny, or results in the denial of, employment rights, privileges, or benefits because of a person's race, religious creed, color, national origin, ancestry, military and veterans status, physical or mental disability, medical condition, genetic characteristics or information, denial of family and medical care leave, marital status, sexual orientation, sex (including gender, gender identity, gender expression, transgender, pregnancy, childbirth and breastfeeding), political affiliation, age (40 and older), concerted labor activity, or any other prohibition identified under state and federal law. The following are examples of conduct that may constitute discrimination:

1. Soliciting applications from a source where all or most of potential workers are of the same race or color.

2. Considering a person's gender as the basis for differences in pay, work assignments, performance evaluations, training, discipline, or any other area of employment; and

3. Questioning a job applicant about the existence, nature and severity of a disability.

B. "Harassment," as used in this policy, consists of any conduct affecting another person because of his or her race, religious creed, color, national origin, ancestry, military and veterans status, physical or mental disability, medical condition, genetic characteristics or information, denial of family and medical care leave, marital status, sexual orientation, sex (including gender, gender identity, gender expression, transgender, pregnancy, childbirth and breastfeeding), political affiliation, age (40 and older), concerted labor activity, or any other category or attribute identified under state and federal law when such conduct has the purpose or the effect of: (1) creating an intimidating, hostile or offensive work environment; (2) unreasonably interfering with the employee's or non-employee's work performance; or (3) EXHIBIT 2

EXHIBIT C
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 4 of 14

DISCRIMINATION AND

HARASSMENT POLICY
Effective Date: Revised From:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 otherwise adversely affecting an employee's or non-employee's employment opportunities.

Harassment may take many forms, including, but not limited to, the following examples:

1. Verbal Harassment: Epithets, derogatory and offensive comments or slurs based on race, religion, color, national origin, ancestry, physical or mental disability, marital status, pregnancy, medical condition, gender, sexual orientation, political affiliation, age, or any other category or attribute identified under state and federal law.

2. Physical Harassment: Assault, impeding or blocking movement that results in the physical interference with normal work or movement on the basis of race, religion, color, national origin, ancestry, physical or mental disability, marital status, pregnancy, medical condition, gender, sexual orientation, political affiliation, age, or any other category or attribute identified under state and federal law.

3. Visual Harassment: The displaying of posters, photography, notices, bulletins, e-mails, cartoons or drawings with derogatory and offensive content based on race, religion, color, national origin, ancestry, physical or mental disability, marital status, pregnancy, medical condition, gender, sexual orientation, political affiliation, age, or any other category or attribute identified under state and federal law.

C. "Sexual harassment," as used in this policy, is a subcategory of harassment, and is specifically defined by law as unwanted sexual advances, requests for sexual favors or visual, verbal or physical conduct of a sexual nature when:

1. Submission to such conduct is made a term or condition of employment; or

2. Submission to or rejection of such conduct is used as a basis for employment decisions affecting the individual; or
EXHIBIT 2

EXHIBIT C
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 5 of 14

DISCRIMINATION AND

HARASSMENT POLICY
Effective Date: Revised From:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93

3. Such conduct has the purpose or effect of unreasonably interfering with an employee's or non-employee's work performance or creating an intimidating, hostile or offensive working environment because of the persistent, severe or pervasive nature of the conduct.

Examples of Sexual Harassment include, but are not limited to the following:
a. Unwelcome sexual overtures or propositions.
b. Offering employment benefits or status in exchange for sexual favors.
c. Making or threatening retaliation after a negative response to sexual advances.
d. Visual conduct such as leering, making sexual gestures, displaying sexually suggestive objects or pictures, cartoons, calendars or posters.
e. Verbal conduct such as using epithets or slurs, telling sexually explicit jokes, or making derogatory or suggestive comments about a person's body or dress.
f. Written communications of a sexual nature distributed in hard copy, soft copy or via a computer network.
g. Verbal abuse of a sexual nature, graphic verbal commentary about an individual's body, sexually degrading words to describe an individual, suggestive or obscene letters, notes or invitations.
h. Physical conduct such as touching, assaulting, impeding or blocking movements.

EXHIBIT 2

EXHIBIT C
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 6 of 14
DISCRIMINATION AND Effective Date:

HARASSMENT POLICY
Revised From:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95. 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 i. Retaliation for making harassment reports or threatening to report harassment.

D. Affordable Care Act (ACA) Anti-Retaliation
Pursuant to section §1558 of the Affordable Care Act, the City prohibits discrimination or retaliation towards any employee who:

1. Receives a health insurance tax credit or subsidy through the Health Care "Marketplace" or "Exchange", by which can trigger a penalty payable by the employer;

2. Reports potential violations of protections afforded under Title I of the Act, which provides guaranteed availability protections among other things;

3. Testifies in a proceeding concerning such violation;

4. Assists or participates in a proceeding concerning a violation; or

5. Objects to, or refuses to participate in, any activity, policy, practice, or assigned task that the employee reasonably believes to be in violation of any provision of the Title I of the Act.

An employee who believes that he or she has been discharged or otherwise discriminated against in violation of section §1558 of the Affordable Care Act may seek relief in accordance with the procedures, notifications, burdens of proof, remedies, and statutes of limitation set forth in section 2087(b) of title 15, United States Code.

IV. REPORTING AND COMPLAINT PROCEDURES
A. Immediate Action Required
The City's reporting and complaint procedures provide for an immediate, thorough and objective investigation of discrimination or harassment claims, appropriate disciplinary action taken against any person found to have engaged in prohibited behavior, and appropriate alternative remedies to any EXHIBIT 2

EXHIBIT C
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 7 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 employee or non-employee subject to discrimination or harassment. To accomplish this, such incidents must be reported immediately to a supervisor or manager.

1. Employee's and Non-Employee's Responsibilities when Subjected to Discrimination and/or Harassment
a. Employees or non-employees who believe they have been subjected to discrimination or harassment, or are aware of discrimination or harassment against others, shall report the situation immediately to his/her supervisor or manager, except as specified in subsection (b), below. Employees and non­ employees shall report any such incidents occurring in the workplace, whether committed by coworkers, supervisors or managers, or third persons doing business with the City, such as customers or vendors, or other non-employees. If
comfortable doing so, an employee or non-employee who has a complaint of discrimination or harassment is encouraged to directly inform the person(s) engaging in the behavior that such conduct is offensive and insist the behavior to stop.
b. Employees and non-employees must immediately contact a supervisor or manager to register a complaint of discrimination or harassment, unless that supervisor or manager is the individual engaging in the unwanted behavior. In that case, the employee or non-employee may contact someone at the next supervisory level. If the employee or non-employee feels uncomfortable dealing directly with his or her immediate supervisor or manager, he or she may contact the department head, or the Director of Human Resources (or either of their designees) to register a complaint of discrimination or harassment.
c. Employees and non-employees may file a formal complaint of harassment or discrimination with their department head or EXHIBIT 2

EXHIBIT C
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 8 of 14

DISCRIMINATION AND

HARASSMENT POLICY
Effective Date: Revised From:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment In the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 with Human Resources. To assist the City in conducting a thorough investigation, complaints shall be submitted in writing and shall include specific details of the incident(s), the names of the individuals involved, the names of any witnesses, and any documentary evidence (notes, pictures, cartoons, etc.) that will corroborate the allegations.
d. Employees and non-employees shall immediately report any retaliation to a supervisor, manager, department head or Director of Human Resources (or designee). All retaliation complaints shall be immediately, objectively and thoroughly investigated in accordance with the investigation procedures.

If a report of retaliation is substantiated, appropriate disciplinary action, up to and including discharge shall be taken.

2. Supervisor's or Manager's Responsibilities to Eliminate Discrimination and/or Harassment
a. A supervisor or manager is responsible for enforcing the City's discrimination and harassment policy. Supervisors or
managers must ensure that all employees and non-employees are aware of the City's policy through open discussion of the policy at staff meetings and by posting the policy in a conspicuous location accessible to all staff members.
b. A supervisor or manager shall be cognizant of employees' and non-employees' behavior and shall not permit any employee or non-employee under their supervision to be subjected to or engage in any conduct prohibited by this policy.
c. A supervisor or manager who observes conduct prohibited by this policy shall immediately direct the employee or non­ employee to cease the conduct.

EXHIBIT 2

EXHIBIT C
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 9 of 14
DISCRIMINATION AND Revised From:

HARASSMENT POLICY
Effective Date:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 d. A supervisor or manager who receives a complaint of
prohibited conduct is required to take the complaint seriously, and report the matter immediately to the department head; be supportive of the complainant; ensure there is no retaliation against the complainant; conduct an internal fact-finding review into the allegations; obtain as much detailed information as possible; thoroughly document the findings; communicate in written form to the parties the resolution of the complaint; and report to and consult with the Human Resources Department promptly, without delay.

B. Confidentiality. The City will make every effort to protect the privacy and confidentiality of all parties involved, as well as any information and/or documentation obtained, to the extent possible consistent with a thorough investigation.

C. Penalty for Non-Compliance. The City shall take disciplinary action, up to and including discharge, against any supervisor or manager who fails in his/her responsibility to take immediate action in response to an employee's or non-employee's complaint of discrimination or harassment. Further, such disciplinary action shall be taken against a supervisor or manager who fails to stop discriminatory or harassing conduct committed in his/her presence or to stop such conduct about which the supervisor or manager has knowledge.

V. INVESTIGATION PROCEDURES
A. Determination of Responsibility for Investigation
If a formal complaint is filed with the department head or the Director of Human Resources (or either of their designees), the department head and the Director of Human Resources shall consult with one another to determine whether the department or Human Resources shall conduct the fact-finding investigation into the allegations. Either the department head or the Director of Human Resources (or either of their designees), depending on who is EXHIBIT 2

EXHIBIT C
Subject:

B.

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No.10 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment In the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 responsible for the investigation, shall issue written notification to the complainant and alleged harasser(s). The notification shall specify the nature of the complaint, and inform the parties that an investigation into the allegations of discrimination and/or harassment shall be conducted.

Investigative Guidelines
The investigation shall include the following steps taken in the order best suited to the circumstances:

1. Identify and preserve the evidence.

2. Confirm the name and position of the complainant. Interview the complainant.

3. Allow the complainant the opportunity to place the complaint in writing.

4. Obtain the identity of the alleged harasser(s).

5. Obtain as many details as possible regarding the incident(s) that prompted the complaint, including the number of occurrences, dates, times, locations, and witnesses (if applicable).

6. Ascertain how the complainant felt about the alleged incident when it occurred; complainant's response(s) to the alleged behavior; and witness statements (if applicable).

7. Ascertain if any threats or promises were made in connection with the alleged harassment.

8. Ascertain if the complainant knows of or suspects that there are other victims of harassment by the same person(s).

9. Ascertain whether the complainant has spoken to anyone, especially EXHIBIT 2

EXHIBIT C
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 11 of 14

DISCRIMINATION AND

HARASSMENT POLICY
Effective Date: Revised From:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment m the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 supervisors, about the harassment.

10. Ascertain what resolution would be acceptable to the complainant.

11. Interview the alleged harasser to get his or her side of the story, including any possible motivation for a false allegation.

12. Interview witnesses who were identified by the complainant regarding the alleged harasser or other persons identified during the investigation.

13. Interview witnesses who were identified by the alleged harasser or other persons identified during the investigation.

14. Advise all participants that the investigation is "confidential" and not to engage in any retaliatory conduct, as such conduct is subject to disciplinary action up to and including discharge. Confidentiality will be maintained to the extent possible. An individual who is interviewed during the course of an investigation is prohibited from discussing the substance of the interview, except as otherwise directed by a supervisor or the Director of Human Resources. Any individual who discusses the content of an investigatory interview will be subject to discipline or other appropriate sanction.

15. Conduct follow-up interviews, if warranted.

16. Prepare report of findings and discuss with management and designated legal staff.

VI. RESPONDING TO THE COMPLAINT
A. Following the completion of the fact-finding investigation, either the department head or the Director of Human Resources (or either of their designees), depending on who is responsible for the investigation, shall EXHIBIT 2

EXHIBIT C
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No.12 of 14
DISCRIMINATION AND Effective Date: Revised From: HARASSMENT POLICY 7/27/09 5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 make a report of findings, along with a recommendation regarding the appropriate remedial action to be taken, if warranted. The recommendation shall be made after reviewing the findings of the investigation, giving consideration to all factual information, the nature of the alleged conduct, and the totality of the circumstances. If the investigation was conducted by the Director of Human Resources, or designee, the Director, or designee, shall confer with the affected department head and both shall concur on the remedial action to be taken, if any. If the investigation was conducted by the department head, the department head shall confer with the Director of Human Resources prior to making the report of findings and both shall concur on the remedial action to be taken, if any.

B. If either the department head or the Director of Human Resources does not concur with the findings and recommendation of the other, the City Attorney (or designee) shall review and resolve the matter in dispute.

C. Report of findings and recommendation shall be treated as a confidential document and no other distribution shall be made without first consulting with the City Attorney's Office. A completed investigation report will not be disclosed, except as it is deemed necessary to support a disciplinary action, to take remedial action, to defend the City in adversarial proceedings, or to comply with the law or court order.

D. Either the department head or the Director of Human Resources (or either of their designees), depending on who is responsible for the investigation shall provide a written response to the complainant and the person alleged to have committed the misconduct, discrimination and/or harassment. The response shall include a copy of the City's discrimination and harassment policy and a memorandum indicating the City's determination as to whether the complaint is:

1. Unsustained: The investigation failed to disclose sufficient evidence to substantiate the allegation(s).

2. Unfounded: The investigation proved that the act(s) or omission(s) EXHIBIT 2

EXHIBIT C

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Subject: Directive No. HR-15 Page No. 13 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09

3. 5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 complained of did not occur. The finding also applies when the individual employee(s) named in the complaint were not involved in the act(s) or omission(s) alleged.

Sustained: The investigation disclosed sufficient evidence to substantiate the allegation(s) made in the complaint; appropriate action will be taken.

E. Details regarding any specific fact-findings or disciplinary action to be taken will not be communicated to the complainant. The City Attorney shall review the response for legal sufficiency before dissemination.

F. The City shall close and retain the investigation file, in accordance with applicable laws, regulations, and City policy regarding retention of City records.

VII. DISCIPLINE
Disciplinary action imposed as a result of any investigation conducted pursuant to this policy shall be commensurate with the severity of the offense, up to and including discharge, even for a first offense.

VIII. ALTERNATIVE REMEDIES
If upon exhausting all internal remedies to file, investigate, and respond to a charges of discrimination/harassment, pursuant to title VII of the Federal Civil Rights Act of 1964 (42 U.S.C §§ 2000e et seq.), any person has a right to file a charge of discrimination/harassment with the Equal Employment Opportunity Commission ("EEOC"). In addition, pursuant to the California Fair Employment and Housing Act (Gov. Code §§ 12900 - 12996.) a person may also file a complaint of discrimination/harassment with the California Department of Fair Employment and Housing ("DFEH"). Employees or non-employees who believe that they have been subjected to discrimination/harassment may file a complaint with either of these EXHIBIT 2

EXHIBIT C

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Subject: Directive No. HR-15 Page No. 14 of 14

DISCRIMINATION AND

HARASSMENT POLICY
Effective Date: Revised From:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 agencies. Both the EEOC and DFEH serve as neutral fact-finders and attempt to assist parties in resolving disputes voluntarily.

IX. COMMUNICATION OF POLICY
This policy shall be provided to all managers, supervisors, employees, volunteers, unpaid interns, agents or contractors of the City and shall be posted in the appropriate places. All employees shall participate in City approved harassment awareness training as directed by management or Human Resources; and all supervisors, as required by law, shall participate in City approved interactive harassment awareness training and education sessions at least once every two years, or as otherwise specified by law.

APPROVED:
c:r��SON

CITY MANAGER
::ODMA\GRPWISE\COS.PER.PER_Library:96180.1
EXHIBIT 2

EXHIBIT C
Bond# 070220022
Premium: $15,700.00

BOND FOR FAITHFUL PERFORMANCE
KNOW ALL MEN BY THESE PRESENTS:

That we, TEROCONS, INC., a STATE OF CALIFORNIA CORPORATION, as Principal and Ihe Ohio Casualty Insurance Company
--� a corporation, organized and existing under the laws of the State of New Hampshire __ and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, as obligee, in the just and full sum of SEVEN HUNDRED EIGHTY-FIVE THOUSAND AND 00/100 DOLLARS ($785,00.00), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to the said CITY, the said Principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.

The condition of the foregoing obligation is such that the above bounded Principal has simultaneously entered into a contract with the CITY, to do and perform the following work, to wit:

ADA CURB RAMP INSTALLATION
(PROJECT NO. WD23004)
NOW, THEREFORE, if the above bounded Principal, CONTRACTOR, Company or
Corporation or its subcontractor, shall well and truly perform the work contracted to be done under said contract, then this obligation to be null and void; otherwise to remain in full force and effect.

No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract, or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY, and no forbearance on the part of the
said ·cITY shall operate to relieve any Surety or Sureties from liability on this bond, and
consent by said Surety is hereby given, and the said Surety hereby waives the EXHIBIT 2

provisions of Sections 2819 and 2845 of the Civil Code of the State of California.

SIGNED AND SEALED on October 5th, 2023 ---------------- Terocons, Inc.

APPROVED AS TO SURETY: By j};:f l!_;M;j_ �

RINCIPAL
The Ohio Casualty Insmance Company
SURETY
APPROVED AS TO FORM & CONTENT:

LORI M. ASUNCION

OFFICE OF THE CITY ATTORNEY
By �_l1?.JW
Brad Bahl, A0RNEY-IN-FACT
By:----------

DEPUTY CITY ATTORNEY
EXHIBIT 2

CALIFORNIA ACKNOWLEDGMENT CIVIL CODE § 1189
�&:liOOar:a::arneBmt se □ o o □a□�• e:o:samt&t203'08Ct0lJC□OE MJiOI HO l:1 a BB:£ DJ Ole! 3 I 0,0:

A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.

State of California
} County of __ C_o_n_t_ra _C_o_s_t_a _____ _
on October 5th, 2023
Date
before me, __ M_.A_. _A_tw_a _te_r_, _N_o_ta_ry_P_u_b _lic _______ � Here Insert Name and Title of the Officer
personally appeared _B_ra_d_B_a_h_l ________________________ _ Name(s) of Signer(s)
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. i e e e e e e e �-<?
;- • • �•, M.A. AT'WATE�
•
� • ; Notari Pt:blic - Coliior,ia �
� t� Contra Coste Co�rtv �
z .,• Commission:/ 23576.:3 [j
My Comm. Expires May 14. 2025 ri
Place Notary Seal and/or Stamp Above
I certify under PENAL TY OF PERJURY under the
laws of the State of California that the foregoing
paragraph is true and correct.

WITNESS my hand and official seal.

Signature m .Q ��-
Signature of Notary Public

OPTIONAL
Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document.

Description of Attached Document
Title or Type of Document: ___________________________ _ Document Date: _____________________ Number of Pages: ____ _ Signer(s) Other Than Named Above: ________________________ _ Capacity(ies) Claimed by Signer(s)
Signer's Name: ____________ _
D Corporate Officer - Title(s): _______ _
D Partner - D Limited D General
D Individual D Attorney in Fact
□ Trustee □ Guardian or Conservator
D Other:

Signer is Representing: _________ _
©2019 National Notary Association
Signer's Name:

D Corporate Officer - Title(s): _______ _
□ Partner - □ Limited □ General
□ Individual □ Attorney in Fact
□ Trustee □ Guardian or Conservator
D Other:

Signer is Representing: _________ _
EXHIBIT 2

Bond# 070220022
Premium: Included in Performance Bond

BOND FOR LABOR AND MATERIAL
KNOW ALL MEN BY THESE PRESENTS:

That we, TEROCONS, INC. ,
a STATE OF CALIFORNIA CORPORATION,
as Principal and The Ohio Casualty Insurance Company
under the laws of the State of New Hampshire
corporation, organized and
and duly authorized to
existing
transact
business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, and unto any and all material suppliers, persons, companies, or corporations furnishing materials, provisions, provender or other supplies used in, upon, for or about the performance of the work contemplated to be executed or performed under the contract hereinafter mentioned, and all persons, companies, or corporations renting or hiring teams, or implements of machinery, for or contributing to said work and all persons who perform work or labor upon the same, and all persons who supply both work and materials, and whose claims have not been paid by the contractor, company or corporation in the just and full sum of SEVEN. HUNDRED EIGHTY-FIVE THOUSAND AND 00/100 DOLLARS ($785,00.00), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to said CITY and to said persons jointly and severally, the said principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.

The condition of the foregoing obligations is such that the above bounden Principal has simultaneously entered into a contract of even date herewith, with the CITY, to do and perform the following work, to-wit:

ADA CURB RAMP INSTALLATION
(PROJECT NO. WD23004)
NOW, THEREFORE, if the above bounden Principal, CONTRACTOR, Company or Corporation or its subcontractor, fail to pay for all materials, provisions, provender, or other supplies, or teams, used in, upon, for or about the performance of the work contracted to be done, or for any work or labor done thereon of any kind, the Surety on EXHIBIT 2

this bond will pay the same, in an amount not exceeding the sum specified in this bond, provided that any and all claims hereunder shall be filed and proceedings had in connection
therewith as required by the provisions of Division 3, Part 4, Title 15, Chapter 5, Article 1 of the Civil Code of California, provided that in case suit is brought upon this bond, a reasonable attorney's fee shall be awarded by the Court to the prevailing party in said suit; said attorney's fee to be fixed as costs in said suit, and to be included in the judgment therein rendered.

No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY and no forbearance on the part of the said CITY shall operate to relieve any surety or sureties from liability on this bond, and consent to make such alterations without further notice to or consent by any such surety is hereby given, and the said sureties hereby waive the provisions of Sections 2819 and 2845 of the Civil Code of the State of California.

SIGNED AND SEALED on October 5th, 2023 ----------------- Terocons, Inc.

APPROVED AS TO SURETY: By� MPhlf�

PRINCIPAL
The Ohio Casualty Insurance Company
SURETY
APPROVED AS TO FORM & CONTENT:

LORI M. ASUNCION

OFFICE OF THE CITY ATTORNEY
By: -----------
Brad Bahl, ATTORNEY-IN-FACT
By:-----------

DEPUTY CITY ATTORNEY
EXHIBIT 2

CALIFORNIA ACKNOWLEDGMENT CIVIL CODE § 1189
•as ; 1 D E D OtDO! ft@ 3 d re:no
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.

State of California
County of __ C_o_n_t_ra_C_o_s_t_a _____ _ }
on Octo be r 5th, 2023 before me, __ M_._A_. _A_t_w_a_te_ r_,_N_o_t_a_ry_P_u_b_li_c ______ _ Date Here Insert Name and Title of the Officer
personally appeared _B_r_a_d_B_a_h_l ________________________ _ Name(s) of Signer(s)
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.

Place Notary Seal and/or Stamp Above
I certify under PENAL TY OF PERJURY under the
laws of the State of California that the foregoing
paragraph is true and correct.

WITNESS my hand and official seal.

Signature m Q., � � ,
Signature of Notary Public

OPTIONAL
Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document.

Description of Attached Document
Title or Type of Document: ___________________________ _ Document Date: _____________________ Number of Pages: ____ _ Signer(s) Other Than Named Above: ________________________ _ Capacity(ies) Claimed by Signer(s)
Signer's Name: ____________ _
o Corporate Officer - Title(s): ______ _
□ Partner - □ Limited □ General
□ Individual o Attorney in Fact
□ Trustee □ Guardian or Conservator
□ Other:

Signer is Representing: _________ _
Signer's Name:
□ Corporate Officer - Title(s): _______ _
□ Partner - □ Limited D General
□ Individual D Attorney in Fact
o Trustee □ Guardian or Conservator
□ Other:

Signer is Representing: _________ _
oorno SOW) [ E �00§:00IJ I; I I � D E 6 ii • @:Ji'l9'00'§ OO!ffi8Bffll0 m� kt§ffflt§@j o ll D EJ ©2019 National Notary Association
EXHIBIT 2

.�Libertx
·� Mutual.

SURETY
This Power of Attorney limits the acts of those named herein, and they have no authority to
bind the Company except in the manner and to the extent herein stated. liberty Mutual Insurance Company
The Ohio Casualty Insurance Company
West American Insurance Company

POWER OF ATTORNEY
Certificate No: 8206758-971892
KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casually Insurance Company is a corporation duly organized under the laws of the state of New Hampshire, that liberty Mutual Insurance Company is a corporation duly organized under the laws of the Slate of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the "Companies"), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, Brad Bahl; Dennis A. Sewell; Gordon J. Fischer; Sam Totah
all of the city of Walnut Creek state of CA each individually if there be more than one named, its true and lawful attorney-in-fact to make, execute, seal, acknowledge and dellver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations, in pursuance of these presents and shall be as .binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons.

IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 5th day of November , �-
Liberty Mutual Insurance Company
The Ohio Casualty Insurance Company
West American Insurance Company
gj
• // ,1,-7,/ k ,,; E
* By: .I?'�,/,/ :� .3
a, ......
..:....- ,.;..::..,,.,. ·-..;..:,..,;,, David M. Carey, Assistant Secretary g-.3 � � State of PENNSYLVANIA ss -� E� 0> County of MONTGOMERY .Q >. � � On this 5th day of November , 2021 before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance � i � ""ffi Company, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes !§@ � i therein contained by signing on behalf of the corporations by himself as a duly authorized officer. � �
�-5 IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at King of Prussia, Pennsylvani�, on the day and year first above written. <(SCI) c·- -=- 00 "' "' �---------� a. _Q � Commonweallh of Pmmsylva11la -Notary Seal �
ai o Teresa Pastella, Nolary PublJo A'.--..
d � ·m
Montgomery County V/ i :' _ _ 1 // --1- JI I ,_ E 02
� _#
MycommissionexpiresMarch28,:Z025 By:�"�'-----���.:.:_-�_:_ ___________ 1.9 ?'C � �' CommJsslor111umb1:1r 1126044 - - af ......, 1'-,,"'l �I': r., Member,PennsylvanlaAssoclallon<JfNolanes T eresa Pastella, Notary Public � o O> cn '"'-'l;iRY �-..., oO
"'� ,c��� , ,_� .g12 This Power of Attorney is made and executed pursuant lo and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual � <? o .£: Insurance Company, and West American Insurance Company which resolutions are now in full force and effecl reading as follows: o..o � E - oo ,_ 2 ARTICLE JV - OFFICERS: Section 12. Power of Attorney. Q 0 .E � Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the Pre sident, and subject to such limitation as the Chainnan or the =a..---- ;g r;' President may prescribe, shall appoint such attorneys-in-fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety � � ! � �:�:��!
a
;
l
o�:r
e
�
a
�
i
i��
s
��
o
�:;p::�
iz
b
a
;::it��i!��e
s
���\��:�i��
n
�f !�;
h
s�!��;:�-!��• :��
j
1: ����� ��:!���es:����
i
t�:��:;i�1���
e
�=i�o
o
:::�;:r :��� § �
z B instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney-in-fact under the � � provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority. & � ARTICLE XIII - Execution of Contracts: Section 5. Surely Bonds and Undertakings.

Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shall appoint such attorneys-in-fact, as may be necessary to act in behalf of lhe Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys-in-fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary.

Certificate of Designation - The President of t he Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such altorneys-in­ fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surely obligations.

Autho rization - By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed.

I, Renee C. Llewellyn, the undersigned, Assistant Secretary, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked.

IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 5th day of October , 2023 By: �� Renee C. Llewellyn, Assistant Secretary
LMS-12873 LMIC ocrc WAIC Multi Co 02/21
EXHIBIT 2