Cities Index.
Exhibit 2 - Executed Contract

City Council and Concurrent Authorities
August 20, 2024

Document
Exhibit 2 - Executed Contract
Meeting
August 20, 2024
Body
City Council and Concurrent Authorities
Pages
37
Original file
5.0 MB
Text extracted from the city's file for reading and search. Open the original on legistar1.granicus.com. That file is the official record.

/ CONSTRUCTION CONTRACT
This contract is made and entered into on 31:iolwd ., by and between W.C.

MALONEY, LLC, a (STATE OF CALIFORNIA CORPORATION), with a business address at P.O. BOX 30326, STOCKTON, CA 95213, hereinafter called "CONTRACTOR," and CITY OF STOCKTON, a municipal corporation, hereinafter called "CITY."
WI TN ES SET H:

WHEREAS, plans and specifications for the construction of VAN BUSKIRK BUILDING DEMOLITION (PROJECT NO. WP24025), hereinafter called "PROJECT," were regularly adopted by Council Resolution No. ________ , on --------; and
WHEREAS, the contract for said work was regularly awarded to CONTRACTOR, by Council Resolution No. ________ , on ______ _
NOW, THEREFORE, in consideration of the promises and of the mutual covenants herein contained, the parties hereto expressly agree as follows:

CONTRACTOR agrees:

1. SCOPE OF SERVlCES. To do the work and furnish all the labor, materials, tools, equipment, and insurance required for the construction of PROJECT in accordance with the plans and specifications adopted on ______ , by Council Resolution No. ________ The "contract documents," which include the bid documents, project plans, specifications, all letters of clarification, and the City of Stockton Standard Specifications and Plans, are incorporated into and made a part of this contract by this reference to the same extent as if fully set forth.

2. COMPENSATION. To do and perform the work contemplated hereby in a good and workmanlike manner and to furnish all labor, materials, tools, and equipment necessary therefore at the prices specified in Exhibit A, attached hereto and by reference made a part hereof, under the direction of and to the complete satisfaction of the Director of Public Works of the City of Stockton. Total compensation for services and reimbursement for costs shall not exceed $114,550.00, or as otherwise mutually agreed to in a Contract Change Order.

3. INSURANCE. CONTRACTOR shall not commence any work before obtaining, and shall maintain in force at all times during the duration and performance of this contract, the policies of insurance specified in Exhibit B, which is attached to this contract and incorporated by this reference, and as provided in the "contract documents" including Section 7-1.06 of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27-1213, effective September 27, 2016.

Local Construction Contract- W.C. MALONEY, LLC - PROJECT NO. WP24025 (Updated 10/18/23)

Page 1 of 40 ends

EXHIBIT 2
It shall be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be available to the Additional Insured.

Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any insurance policy or proceeds available to the named Insured:
whichever is greater.

The Additional Insured coverage under the CONTRACTOR's policy shall be "primary and non-contributory" and will not seek contribution from the City of Stockton's insurance or self-insurance and shall be at least as broad as ISO CG 20 01 04 13.

The limits of insurance required in this agreement may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis for the benefit of the City of Stockton (if agreed to in a written contract or agreement) before the City of Stockton's own insurance or self­ insurance shall be called upon to protect it as a named insured.

All self-insured retentions (SIR) must be disclosed to the CITY's Risk Management for approval and shall not reduce the limits of liability. Payment Bond in the amount of the self-insured retention (SIR) may be required.

Policies containing any self-insured retention (SIR) provision shall provide or be endorsed to provide that the SIR may be satisfied by either the named insured or the CITY.

The CITY reserves the right to obtain a full certified copy of any insurance policy and endorsements.

Failure to exercise this right shall not constitute a waiver of right to exercise later.

CONTRACTOR shall maintain insurance as required by this contract to the fullest amount allowed by law and shall maintain insurance for a minimum of five years following the completion of this project. In the event contractor fails to obtain or maintain completed operations coverage as required by this agreement, the City at its sole discretion may purchase the coverage required and the cost will be paid by contractor.

CONTRACTOR agrees to include with all Subcontractors in their subcontract the same requirements and provisions of this agreement including the indemnity and insurance requirements to the extent they apply to the scope of the Subcontractor's work.

Subcontractors hired by CONTRACTOR agree to be bound to CONTRACTOR and the CITY in the same manner and to the same extent as CONTRACTOR is bound to the CITY under the Contract Documents. Subcontractor further agrees to include these same provisions with any Sub-subcontractor. A copy of the CITY Contract Document Indemnity and Insurance provisions will be furnished to the Subcontractor upon request. The Local Construction Contract· W.C. MALONEY, LLC • PROJECT NO. WP24025 (Updated 10/18/23)

Page 2 of 40 ends

EXHIBIT 2
General CONTRACTOR shall require all sub-contractors to provide a valid certificate of insurance and the required endorsements included in the agreement prior to commencement of any work and contractor will provide proof of compliance to the City.

4. INDEMNITY AND HOLD HARMLESS. To ,the fullest extent permitted by law, Contractor shall hold harmless, defendi and indemnify City of Stockton and its officers, officials, employees, and volunteers from and against all claims, damages, losses, and expenses including attorney fees arising out of the performance of the work described herein, caused in whole or in part by any negligent act or omission of the Contractor, any subcontractor, anyone directly or indirectly employed by any of them, or anyone for whose acts any of them may be liable, except where ·caused by the active negligence, sole negligence, or will(ul misconduct of the City of Stockton. This obligation is independent of, and shall not in· any way be limited by, the minimum Insurance obligations contained in this agreement. These obligations shall survive the completion or termination of this agreement.

5. STANDARD. PLANS AND SPECIFICATIONS. The performance of said work and the furnishing of said materials shaH be executed in accordance with Section 8-1.048 of the City of Stockton Standard Specifications and Plans as' adopted on September 27, 2016, by Council Resolution No. 2016-09-27-1213, effective September 27, 2016, and the provisions of the issued project specifications.

The Director of Public Works will furnish CONTRACTOR a weekly statement showing the number of days charged to the contract for the preceding week, the number of days specified for completion of the contract, and the number of days remaining to complete the contract. CONTRACTOR will be allowed one (1) week in which to file a written protest setting forth in what respects said weekly statement is incorrect, otherwise the statement shall be deemed to have been accepted by CONTRACTOR as correct.

6. WORKING DAYS .. This work shall be diligently prosecuted to completionI -·-- ·--· ••• ·---· - --- --- ------ -- --·---. before the expiration of 30 WORKING DA VS beginning on the tenth calendar day after the date shown on the Notice to Proceed. It is agreed by the parties to the contract that in case all the work called for under the contract in all parts and requirements, is not finished or completed within the number of days as set forth, damage will be sustained by the CITY, and that it is and will be impracticable and extremely difficult to ascertain the actual damage which CITY will sustain in the event of and by reason of such delay: and it is therefore agreed that CONTRACTOR will pay to CITY the sum of ONE THOUSAND AND NO/100 DOLLARS ($1,000.00) per day for each and every calendar day's delay in finishing the work in excess of the number of days prescribed; and CONTRACTOR agrees to pay said liquidated damages as herein provided, and in case the same are not paid, agrees that CITY, may deduct the amount thereof from any monies due or that may become due CONTRACTOR under the contract.

It is further agreed that in case the work called for under the contract is not finished and completed in all parts and requirements within the number of days as specified, the CITY shall have the right to increase the number of days or not, as may seem best to serve Local Construction Contract· W.C. MALONEY, LLC • PROJECT NO. WP24025 (Updated 10/18123)

Page 3 of 40 ends

EXHIBIT 2
the interest of CITY, and if the CITY decides to increase the said number of days, the CITY shall further have the right to charge to CONTRACTOR, CONTRACTOR's heirs, assigns or sureties, and to deduct from the final payment for the work, all or any part, as may be deemed proper, the liquidated damages as specified or the actual cost of engineering, inspection, superintendence, and other overhead expenses which are directly chargeable to the contract, and which accrue during the period of such extension, whichever is greater, except the cost of final surveys and preparation of final estimate shall not be included in such charges.

A working day shall not include, nor shall CONTRACTOR be assessed with liquidated damages nor the additional cost of engineering and inspection during any delay beyond the time named for the completion of the work caused by acts of God or of the public enemy, acts of CITY, fire, floods, epidemics, quarantine restrictions, strikes, and freight embargoes and subject to approval by the Director of Public Works, inability to get materials ordered by CONTRACTOR or subcontractor due to such causes provided that CONTRACTOR shall notify the Director of Public Works in writing of the causes of delay within five (5) working days from the beginning of any such delay, and the Director shall ascertain the facts and the extent of the delay, and Director's findings of the facts thereon shall be final and conclusive.

If CONTRACTOR is delayed by reason of alterations made in these specifications, or by any act of the Director of Public Works or of the CITY, not contemplated by the contract, the time of completion shall be extended proportionately and CONTRACTOR shall be relieved during the period of such extension of any claim for liquidated damages, engineering or inspection charges or other penalties. CONTRACTOR shall have no claim for any other compensation for any such delay.

7. CONFORMANCE TO APPLICABLE LAWS. Contractor shall comply with all applicable Federal, State, and Municipal laws, rules, and ordinances. Contractor shall not discriminate in the employment of persons or in the provision of services under this Contract on the basis of any legally protected classification, including race, color, national origin, ancestry, sex or religion of such person.
a. TITLE VI
Title VI of the Civil Rights Act of 1964 requires that "no person in the United States shall, on the grounds of race, color, or national origin, be excluded from participation in, be denied the benefits of, or be subjected to discrimination under any program or activity receiving federal financial assistance." (42 USC Section 2000d)
http://www.dol.gov/oasam/regs/statutes/titlevi.htm.

The City of Stockton requires compliance with the requirements of Title VI in all of its programs and activities regardless of funding source. b. DISCRIMINATION AND HARASSMENT POLICY
Local Construction Contract - WC. MALONEY, LLC • PROJECT NO. WP24025

Page 4 of 40 ends

(Updated 10/18/23)
EXHIBIT 2
C.
d.

The City of Stockton has a Discrimination and Harassment Policy Exhibit C. The purpose of this policy is to reaffirm the CITY's commitment to demonstrating respect for all individuals by strictly prohibiting discrimination and harassment, including sexual harassment in the workplace, to define the types of behavior and conduct prohibited by this policy, and to set forth a procedure for reporting, investigating, and resolving complaints of discrimination and harassment in the workplace.

LABOR STANDARDS PROVISIONS/CALIFORNIA LABOR CODE
The bidder shall under�tand that conditions set forth in Chapter 1, Part 7, Division 2 of the California Labor Code shall be considered part of the contract agreement.
httg�:£lle.gjnfo,legjslature.ca.gov/faces/codes displayText.xhtml?lawCode= LAB&d ivision=2. &title=&part= 7 .&chapter= 1 .&article=2.

PREVAILING WAGE
CONTRACTOR and any subcontractor shall pay each employee engaged in the trade or occupation not less than the prevailing hourly wage rate. In accordance with the provisions of Section 1770 of the Labor Code, the Director of Department of Industrial Relations of the State of California has determined the general prevailing wage and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for in Section 1773.1, apprenticeship or other training programs authorized by Section 3093 and similar purposes applicable to the work to be done. CONTRACTOR performing the work under this contract shall obtain a copy of the wage rate determination and shall distribute copies to each subcontractor. As the wage determination for each craft reflects an expiration date, it shall be the prime CONTRACTOR and each subcontractor's responsibility to ensure that the prevailing wage rates of concern is current and paid to the employee.
i. The CONTRACTOR performing the work shall be responsible for obtaining a copy of the State wage rate determination. State wage rates may be obtained at
b,Up://www.dir.ca.gov/OPRL/pwd/Determinations/Nort hern/Northern.pd f. The CONTRACTOR shall be responsible for posting said wage rates at a prominent location at the work site and shall maintain same in a good readable condition for the duration of the work.
ii. Should the CONTRACTOR choose to work on a Saturday, Sunday or on a holiday recognized by the Labor Unions, the CONTRACTOR shall reimburse the CITY the actual cost of engineering, inspection, superintendence, and or other overhead expenses which are directly Local Construction Contract· WC MALONEY. LLC • PROJECT NO. WP24025 (Updated 10/18/23)

Page 5 of 40 ends

EXHIBIT 2
chargeable to the contract. Should such work be undertaken at the request of the CITY, reimbursement will not be required. To conform strictly with the provisions of Division 21 Part 7, Chapter 11 Article 2, of the Labor Code of the State of California. To forfeit as a penalty to CITY the sum of TWENTY-FIVE ANO NO/100 DOLLARS ($25.00) for each laborer. worker. or mechanic employed by CONTRACTOR, or by any subcontractor under CONTRACTOR, in the execution of this contract, for each calendar day during which any laborer. worker, or mechanic is required or permitted to work more than �ight (8) hours and who is not paid the general prevailing rate of per diem wages for holiday and overtime work in violation of the provisions of Sections 1770 to 1781 of the Labor Code of the State of California. That all sums forfeited under the provisions of the foregoing sections shall be deducted from the payments to be made under the terms of this contract.
iii. The CONTRACTOR to whom the contract is awarded shall ensure that the prime and each subcontractor will in accordance with Section 1776 of the Labor Code, maintain certified payroll records. A copy of said records shall be provided with each invoice to the Public Works Department, Attention Contract Compliance Officer. It shall be the CONTRACTOR'S responsibility to obtain copies of the current prevailing wage rate determination for all subcontractors. Additionally, certified payroll records must be uploaded to the DIR website as required by labor code.
iv. The CONTRACTOR shall comply with the provisions established in Section 1777.5 of the Labor Code concerning the 1) certified approval by local joint apprenticeship committees for the employment and training of apprentices, and 2) contribution of funds to administer and conduct apprenticeship programs, if applicable to the job. e. LOCAL l;MPLOYMENT ORDIN.ANCE
Pursuant to Stockton Municipal Code Section 3.68.095 the CONTRACTOR and all subcontractors shall make a good faith effort to employ at least 50 percent of the workforce on this project from local residents, as measured by total labor work hours. Failure of any CONTRACTOR or subcontractor to comply with these requirements shall be deemed a material breach of the contract or subcontract. CONTRACTORS and subcontractors shall maintain records necessary for monitoring their compliance with section

3.68.095.
f. SANCTIONS
Deliverables must conform with all applicable federal, state, and local Local Construction Contract· W.C. MALONEY, LLC • PROJECT NO. WP24025 (Updated 10/18/23)

Page 6 of 40 ends

EXHIBIT 2
laws. Such conformity includes compliance with federal sanctions, and Contractor certifies that it has not and will not engage in prohibited transactions with sanctioned persons or entities.

CITY agrees:

8. COMPENSATION. To pay CONTRACTOR for the work herein
contemplated in the following manner: Progress payments will be made on or about the first day of each calendar month, in such sum as shall make the aggregate of payment up to such day equal to ninety-five percent (95%) of the proportional contract price, upon the basis of the progress certificate of the Director of Public Works as to the amount of work done and the proportional amount of the contract price represented therefore; and all of the remaining part of the contract price not as aforesaid paid, shall be paid at the expiration of thirty-five (35) days from the completion of said work of construction and the certification by the Director of Public Works of such completion.

9. SECURITIES. Pursuant to Section 22300 of the Public Contract Code, CONTRACTOR will be permitted, at its request and sole expense, to substitute securities for any monies withheld by the CITY to ensure performance under the contract. Said securities will be deposited either with the C ITV or with a State or federally chartered bank as escrow agent. Securities eligible for this substitution are those listed in Section 16430 of the California Government Code or bank or savings and loan certificates of deposit.

CONTRACTOR shall be the beneficial owner of any securities substituted for monies withheld and shall receive any interest thereon.

10. CHANGE ORDERS. CITY reserves the right to make such alterations, deviations, additions to or omissions from the plans and specifications, including the right to increase or decrease the quantity of any item or portion of the work, as may be deemed by the Engineer to be necessary or advisable and to require such extra work as may be determined by the Engineer to be required for the proper completion or construction of the whole work contemplated.

Any such changes will be set forth in a contract change order which will specify, in addition to the work done in connection with the change made, adjustment of contract time, if any, and the basis of compensation for such work. A contract change order will not become effective until approved by the City Manager and/or the City Council.

Processing of change orders shall be in accordance with Section 4-1.0SA of the City of Stockton Standard Specifications and Plans as adopted by Council on September 27, 2016, by Resolution No. 2016-09-27-1213, effective September 27, 2016, or as otherwise amended by Council. When the compensation for an item of work is subject to adjustment under the provisions .. of Standard Specifications and Plans, Section 4-1.05A, CONTRACTOR shall, upon request,·promptly furnish the Engineer with adequate detailed cost data for such item of work.
local Construction Contract· WC. MALONEY, LLC • PROJECT NO WP24025 (Updated 10/18/23)

Page 7 of 40 ends

EXHIBIT 2

11. AUDITS. CITY reserves the right to periodically audit all charges made by CONTRACTOR to CITY for services under the contract. Upon request, CONTRACTOR agrees to furnish CITY, or a designated representative, with necessary information and assistance.

CONTRACTOR agrees that CITY or its delegate will have the right to review, obtain and copy all records pertaining to performance of the contract. CONTRACTOR agrees to provide CITY or its delegate with any relevant information requested and shall permit CITY or its delegate access to its premises, upon reasonable notice, during normal business hours for the purpose of interviewing employees and inspecting and copying such books, records, accounts, and other material that may be relevant to a matter under investigation for the purpose of determining compliance with this requirement.

CONTRACTOR further agrees to maintain such records for a period of three (3) years after final payment under the contract.

12. WAIVER. It is expressly understood and agreed by and between the parties hereto that a waiver of any of the conditions of this contract shall not be considered a waiver of any of the other conditions thereof.

It is further understood and agreed by and between the parties hereto that time is of the essence of this contract in all respects.

IN WITNESS WHEREOF, the parties hereto have hereunto affixed their hands and seals the day and year first above written.

ATTEST:

C.ivELIZA R. GARZA
\ r � CITY CLERK
APPROVED AS TO FORM & CONTENT:

LORI M. ASUNCION

OFFICE OF THE CITY ATTORNEY
By:-------------

DEPUTY CITY ATTORNEY
CITY:

Y BLACK

CITY MANAGER
31·54%g2l) __ _
Tax Identification No.

Local Construction Contract -W.C. MALONEY, LLC - PROJECT NO. WP24025 (Updated 10/18/23)

Page 8 of 40 ends

EXHIBIT 2
� IK4 MIIM'II J/IJ
� A Precizlon Partners Company

EXHIBIT A
4020 Newton Road P.O. Box 30328
Stockton. CA96213
2099421129
[email protected]
Project: Van Buskirk Building Demolition REV2
>roposal submitted by: Jeremy Burt
:maU: [email protected]
>hone: 530..277-4094
>ear Respected Client:

VC Maloney Is pleased to submit our pricing and proposal and we greatly appreciate the opportunity. As an irganlzation we have well over 100 years of experience performing demolition and abatement work across the 1pectrum. In this proposal you will find the details and limitations of our scope.

Ve are bidding on the following Items:
•rovide materials, labor, and equipment for the abatement of materials containing greater than 1 % asbestos and lemolitlon of noted buildings 1-9 in supplied Exhi�it D and FACS survey dated 1/1/2019. AH slabs and pumps to remain Is discussed during mandatory site visit 12/8/23.
,109,550.00
1dd for coordination cl PG&E gas and power disoonnects
5,000.00
·otal:
114,550.00
ems not expressly included in this proposal shall be deemed excluded from subcontractors soope of work. :hanges or deletions to this quote, bid Item list or terms and conditions, must be done PRIOR to bid time only. i*INCLUDED*H
'ermits
iust Control
1ump Fees
.fr Quality Notification Fees
love-ins (1)
dd for Each Extra Mobilization ($2,500.00)
•EXCLUSIONS*,..
o Allowance For Local Hire
nglneering Costs or Services
spectlon Costs
:>tholing of underground utiftties
Ulities Protection, Shoring/Bracing, Disoonnect/Safe Off or Capping 'CM will contact USA and obtain a ticket# for our work area. Any locating of utilities that falls outside of USA rlsdiction, will be the G.CJOwners responsibility to Identify and layout.

Page 9 of 40 ends

EXHIBIT 2
Base Rock Removal
Traffic Control (Auto/Pedestrian)
Barricades (Auto/Pedestrian)
Temporary Fencing
Site Security
Any Unforeseen Objects Below Grade Unless Noted in Quote.

Temporary Shoring or Bracing
De-Watering
Backfil and Compaction
Installation And Maintenance Of (S.W.P.P.P.)
Street Sweeping
Protective Covering
Rough Grade Only, Fine Grading by Others
Relocate/Salvage i.e.Savlng or Salvaging for Relocation or Reuse on Project a OWners Reuse Temporary Lighting
Saw Cutting
Excavation For our Removal Only
Treated Wood Waste Disposal not Included in Bid
" .. * Additional requirements**•
Layout Of Work, Le. Specific Markings In Paint lndentifylng Exact Removal Limits Lane Closures if Necessary
Free Access to Water and Power at Work Location
Access to Work Areas
Work to be Perfonned During Normal Hours.

All Salvage Material Becomes Property ofW.C. Maloney Inc.

Stand-By Time Beyond the Control of W.C. Maloney Inc. Will Be Subject b Additional Charges.

EXHIBiT A
--AN ASBESTOS SURVEY WILL BE REQUIRED PRIOR TO DEMOLITI ON (NOT INCLUDED IN PRICE) PLEASE ALLOW FOR A 10 WORKING DAY NOTIFICATION IN YOUR SCHEDULE TO AIR QUALITY CONTROL PRIOR TO

ANY DEMOLITION
-WE REQUIRE A COPY OF THE DEMOLITION PERMIT FOR OUR RECORDS, PRIOR TO STARTING ANY WORK.

W.C. MALONEY'S INDEMNITY OBLIGATIONS AND OTHER PAYMENT OBLIGATIONS UNDER THIS

SUBCONTRACT ARE EXPRESSLY LIMITED TO ANO SHALL NOT EXCEED OBLIGATIONS, LOSSES, DAMA GES, ETC., COVERED BY AND ACTUALLY PAID BY W.C.MALONEV'S INSURANCE AS REQUIRED IN THIS SUBCONTRACT.
•THIS QUOTE REPRESENTS MY FULL SCOPE OF WORK AND SHALL BE MADE PART OF THE SUBCONTRACT ALONG WITH THE 'W.C. MALONEY TERMS AND CONDITIONS".

Contractors License #718243 Class A & C-21
D.I.R. #1000868882
We Are Signatory To The Labofers & Operating Engineers Unions. :luote Expiration.

The offer to perform the work for the price and terms set forth in the Quote and Agreement Is valid for thirty (30) days and may be contingent upon a satisfactory credit report. The Quote shall ,be attached and ncorporated by reference Into any subcontract returned to Subcontractor for signatur e.

Page 10 of 40 ends

EXHIBIT 2

EXHIBIT A
�cope of Work.
terns not expressly included in the attached Quote shall be deemed excluded from W.C. Maloney's (WCM) ;cope of work, including, without liml•tion: Layout, traffic control; permits; utilities; air quality control and nonitoring; erosion control; including without limitation, blocking storm drains, or catch basins; water or dust ,arriers; patching; shoring; access to work area; safety rails/barriers; protection of open areas resulting from 1aw cuts, core holes, demolition or excavation work performed by WCM and directed by others, or open treas; prot�ction from water. du�t damage or staining; water for dust control; and hazardous conditions, ncfuding removal. WCM shall only be bound to the schedule for work as stated in bid or Quote or according o a schedule which WCM and Owner/Contractor have expressly approved in writing . . imitatiOA of Llabilfty.
a) IN NO EVENT SHALL WOM BE LIABLE TO CONTRACTOR/OWNER OR ANY THIRD PARTY FOR ANY .ass OF USE, REVENUE OR PROFfT OR LOSS OF DATA OR DIMINUTION IN VALUE, OR FOR ANY .IQUIDATED, CONSEQUENTIAL, INDIRECT, INCIDENTAL, SPECIAL, EXEMPLARY, OR PUNITIVE -AMAGES WHETHER ARISING OUT OF BREACH OF CONTRACT, TORT (INCLUDING NEGLIGENCE) )R OTHERWISE. REGARDLESS OF WHETHER SUCH DAMAGES WERE FORESEEABLE AND �ETHER OR NOT WCM HAS BEEN ADViSED OF THE POSSIBIL.ITY OF SUCH DAMAGES, AND

IOTWITHSTANDING THE FAILURE OF ANY AGREED OR OTHER REMEDY OF ITS ESSENTIAL 1URP.OSE. fN NO EVENT SHALL WCM AGGREGATE LIABILITY ARISING OUT OF ,OR RELATED TO HIS AGREEMENT, WHETt-ER ARISING OUT OF OR RELATED TO BREACH OF CONTRACT, TORT

NCLUDING NEGLIGENCE) OR OTHERWISE, EXCEED THE TOTAL OF THE AMOUNTS PAID TO WCM OR THE SERVICES PROVIDED.
>) The.limitation of liability set fonh herein shall not apply to lfabllity resulting from WCM' gross negligence or 1lllful misoonduct
:) Contractor or Owner, as tl;le case may be, should expect a minimum amount of damage or marring from 1e abatement process as a result of tape and adhesive which may be used to isolate the work areas. WCM ,all not be responsible for such damage. Further, if It is necessary for WCM to remove fixtures and /or 1binets in order to access the asbesk>s containing material, WCM wllf not be responsible for any damage to • replacement of these materials.
ommencement and Progress of Work; Delay.
'CM will proseGute the work dllJgently to completion and will conform to any progress schedule established , Contractor or owner. WCM will coordinate work with Contractor or Owner and other subcontractors so that ere will be no delay k> or interference with other work on the project. WCM shan not be liable for delays in its immencement of the Work caused by the Contractor, Owner or other subcontractors. aterial Price Increase.
the event that there are signfflcant Increases in the prices for materials, supplies, fuel and/or equipment

Page 11 of 40 ends

EXHIBIT 2
·� ll4 Mltllll lld
� A Precillon Partners Company

EXHIBIT A
(collectively, •Materials") for the work to be perfonned _hereunder, between the date of this Quote and the date such Materials are purchased, WCM shall be entitled to additional compensation as desaibed herein. A Slgnificant,Price Increase shaU be defined herein as an Increase as to any specific Items of Materials of twenty percent (20%) or more. In the event a significant increase In price occurs, the contract price shall automatically be increased, a change order may be Issued, and Owner/Contractor agrees to pay to WCM the Increased oontraot price. Upon reasonable request by Owner/Contraetor, WCM is entitled to demonstrate a Significant Price Increase thraugh the use of .quotes, supplier list prices, invoices, or receipts. WCM shall In no way be responsible for Increased prices of materials when <a.tseH by delays shortages, or unav,ilablllty of materials due to conditions not caused by WOM.

Payment.

M payments, Including payments for extra wort< or payments hereunder, shall be made in accordance with the California CivH Code, prompt payment statutes, l>ut In no event shall payment be made later than ten (10) days from the date Contractor receives payment for the work to be performed or within thirty (30) days of request for payment to Owner. In addition to any other remedies available: work not paid for In a 'timely fashion shall be subje-ct to a late cha[De, of 2%, compounded rnonthiy and any unpaid amounts shall be subject to Interest at 18% per annum. In the event WCM is foreed to fife a claim or lawsuit In order-to enforce any agreement and/or collect any fees dtte hereunder, Owner or Contracte>'r will be responsltile'for all sucH rees, including any and al reasonable' attorneys fees. Notwfth'standing anything herein to the contrary, WCM shall have the right. to stop work in the event·• falls to receive' payment for any work following 45 days after satisfactory performance thereof. Payments shaft not Include a deduction for retention unless• otherwise 1:1greed in writing.

Back Charges and OpportunJty to Cure Defects.

Back charges will not be paid unless Owner/Contractor. (a) noflfies WCM within seventy-two (72) hours of :tiscovery of a defect in WCM' work; (b) WCM provides written approval � any remedial work is performed; and (c) OWner/Contractor provides WCM a reasonable opportunity to cure the alleged defect. 3ack charges may not be deducted from payments due;. back charges Instead will be billed. ;I
ndemnlflcation.
ro the greatest extent pennltted by law, Owner and Contractor agrees to defend, indemnify, and hold 1armless WCM and its employees, agents, and officers from and against all claims and suits by Jwner/Contractor or third parties for damages, injuries to persons (Including death), property damages, asses, and expenses including court costs and reasonable attorney's fees, arising out of, or resulting from, NCM's performance under this Agreement. Including all allegations of negfigent or Intentional acts on the >art of WCM, its officers, employees, agents, subcontractors, licensees, or invitees, exce pt for the gross 1egligence or willful misconduct on the part of WCM.
\ccess b Area of Work.

Page 12 of 40 ends

EXHIBIT 2

EXHIBIT A
� lt4 IIAJIM'II W
� A Preclzfon Partners Company
"he party accepting this Agreement agrees to ensure that the area ci work Is free of vehicles, garbage bins, ;torage bins or other blocking Items, or water which would prevent the work called for In this Agreement. ;hould WCM be prevented fom, commencjng work because of vehiefes, garbage bins, storage bins or other 1locking Items, or wet or damp conditions, CK other customer related activity, the accepting party agrees to ,ay WCM the sum of $850.00, which the parties agree is a fair and reasonable calculation of WCM costs for omlng to the work site. The area in which the asbestos is to be removed will be occupied by WCM' erson nel or Its authorized agents and will be off limits to any and all persons during the entire abatement rocess. Proper signage will be posted.
lefauH and Termination.
1 Contractor or Owner fails to perform in accordance with this Agreement, WCM shall give Contractor or 1wner notice of such default, including a description of the defaurt. If Contractor or Owner fails to cure the efault within 72 hours after the notice (time being of the essence), WCM may terminate this Agreement. :ontractor or Owner shall promptly pay, but within thirty (30) days oftenninatlon of this Agreement, WCM for II work performed.

Page 13 of 40 ends

EXHIBIT 2
�xhibit B;
Insurance Requirements
(Demolition)
EXHIBiT B
Contractor shall procure and maintain for the duration of the contract, and for 5 years thereafter, insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his agents, representatives, employees, or subcontractors.

MINIMUM SCOPE AND LIMIT OF INSURANCE
Coverage shall be at least as broad as:

1. Commercial General Liability (CGL): Insurance Services Office (ISO) Form CG 00 01 covering CGL on an "occurrence" basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $2,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit.

2. Automobile Liability: Insurance Services Office Form CA 0001 covering Code 1 (any auto), with limits no less than $2,000,000 per accident for bodily injury and property damage,

3. Workers' Compensation insurance as required by the State of California, with Statutory Limits, and Employers' Liability insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.

4. Contractors Pollution Liability applicable to the work being performed, with a limit no less than $2,000,000 per claim or occurrence and $2,000,000 aggregate per policy period of one year.

5. Surety Bonds as described below.

If the contractor maintains broader coverage and/or higher limits than the minimums shown above, the City of Stockton requires and shall be entitled to the broader coverage and/or the higher limits maintained by the contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City of Stockton.

Self-Insured Retentions

Page 14 of 40 ends

EXHIBIT 2

EXHIBIT B
Self-insured retentions must be declared to and approved by the City of Stockton. The City of Stockton may require the Contractor to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention. The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the named insured or City of Stockton. The CGL and any policies, including Excess liability policies, may not be subject to a self-insured retention (SIR) or deductible that exceeds $25,000 unless approved in writing by City of Stockton. Any and all deductibles and SIRs shall be the sole responsibility of Contractor or subcontractor who procured such insurance and shall not apply to the Indemnified Additional Insured Parties. City of Stockton may deduct from any amounts otherwise due Contractor to fund the SIR/deductible. Policies shall NOT contain any self-insured retention (SIR) provision that limits the satisfaction of the SIR to the Named Insured.

The policy must also provide that Defense costs, including the Allocated Loss Adjustment Expenses, will satisfy the SIR or deductible. City of Stockton reserves the right to obtain a copy of any policies and endorsements for verification.

Other Insurance Provisions
The insurance policies are to contain, or be endorsed to contain, the following provisions:

1. The City of Stockton, its officers, officials, employees, and volunteers are to be covered as additional insureds·on the CGL policy with respect to liability arising out of work or operations performed by or on behalf of the Contractor including materials, parts, or equipment furnished in connection with such work or operations and automobiles owned, leased, hired, or borrowed by or on behalf of the Contractor.

General liability coverage can be provided in the form of an endorsement to the Contractor's insurance (at least as broad as ISO Form CG 20 10 1185 or both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; IDd CG 20 37 forms if later revisions used).

Additional insured Name of Organization shall read "City of Stockton, its officers, officials, employees, and volunteers." Policy shall cover City of Stockton, its officers, officials, employees, and volunteers for all locations work is done under this contract.

2. For any claims related to this project, the Contractor's insurance coverage shall be primary and non-contributory insurance coverage at least as broad as ISO CG 20 01 04 13 as respects the City of Stockton, its officers, officials, employees, and volunteers. Any insurance or self-insurance maintained by the· Oty of Stockton, its officers, officials, employees, or volunteers shall be excess of the Contractor's insurance and shall not contribute with it. This requirement shall also apply to any Excess or Umbrella liability policies. The City of Stockton does not accept endorsements limiting the Contractor's insurance coverage to the sole negligence of the Named Insured.

Page 15 of 40 ends

EXHIBIT 2
EXHIBiT B

3. Each insurance policy required by this clause shall provide that coverage shall not be canceled, except with notice to the City of Stockton.

Claims Made Polle/es (Professional & Pollution only)
If any coverage required is written on a claims-made coverage form:

1. The retroactive date must be shown, and this date must be before the execution date of the contract or the beginning of contract work.

2. Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of contract work.

3. If coverage is cancelled or non-renewed, and not replaced with another claims-made policy form with a retroactive date prior to the contract effective, or start of work date, the Contractor must purchase extended reporting period coverage for a minimum of five (5) years after completion of contract work.

4. A copy of the claims reporting requirements must be submitted to the City of Stockton for review.

5. If the services involve lead-based paint or asbestos identification/remediation, the Contractors Pollution Liability policy shall not contain lead-based paint or asbestos exclusions. If the services involve mold identification/remediation, the Contractors Pollution Liability policy shall not contain a mold exclusion, and the definition of Pollution shall include microbial matter, including mold.

Umbrella or Excess Policies
The Contractor may use Umbrella or Excess Policies to provide the liability limits as required in this agreement. This form of insurance will be acceptable provided that all of the Primary and Umbrella or Excess Policies shall provide all of the insurance coverages herein required, including, but not limited to, primary and non-contributory, additional Insured, Self-Insured Retentions (SIRs}, indemnity, and defense requirements. The Umbrella or Excess policies shall be provided on a true "following form" or broader coverage basis, with coverage at least as broad as provided on the underlying Commercial General Liability insurance. No insurance policies maintained by the Additional Insureds, whether primary or excess, and which also apply to a loss covered hereunder, shall be called upon to contribute to a loss until the Contractor's primary and excess liability policies are exhausted.

Acceptablllty of Insurers
Insurance is to be placed with insurers authorized to conduct business in the state with a current A.M. Best rating of no less than A: VII, unless otherwise acceptable to the City of Stockton.

Page 16 of 40 ends

EXHIBIT 2

EXHIBIT B
Waiver of Subrogation
Contractor hereby agrees to waive rights of subrogation which any insurer of Contractor may acquire from Contractor by virtue of the payment of any loss.

Contractor agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation. The Workers' Compensation policy shall be endorsed with a waiver of subrogation in favor of the City of Stockton for all work performed by the Contractor, its employees, agents and subcontractors.

Verification of Coverage
Contractor shall furnish the City of Stockton with original certificates and amendatory endorsements or copies of the applicable policy language effecting coverage required by this clause and a copy of the Declarations and Endorsements Pages of the CGL and any Excess policies listing all policy endorsements. All certificates and endorsements and copies of the Declarations & Endorsements pages are to be received and approved by the City of Stockton before work commences. However, failure to obtain the required documents prior to the work beginning shall not waive the Contractor's obligation to provide them. The City of Stockton reserves the right to require complete, certified copies of all required insurance policies, Including endorsements required by these specifications, at any time. City of Stockton reserves the right to modify these requirements, Including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances.

Subcontractors
Contractor shall require and verify that all subcontractors maintain insurance meeting all requirements stated herein, and Contractor shall ensure that City of Stockton is an additional insured on insurance required from subcontractors. For CGL coverage, subcontractors shall provide coverage with a form at least as broad as CG 20 38 04 13.

Duration of Coverage
CGL & Excess liability policies for any construction related work, including, but not limited to, maintenance, service, or repair work, shall continue coverage for a minimum of 5 years for Completed Operations liability coverage. Such Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of the contract of work.

Surety Bonds
Contractor shall provide the following Surety Bonds:

1. Bid Bond

2. Performance Bond

3. Payment Bond

Page 17 of 40 ends

EXHIBIT 2
EXHIBiT B

4. Maintenance Bond
Toe Payment Bond and the Performance Bond shall be in a sum equal to the contract price. If the Performance Bond provides for a one-year warranty a separate Maintenance Bond is not necessary. If the warranty period specified in the contract is for longer than one year a Maintenance Bond equal to 10% of the contract price is required. Bonds shall be duly executed by a responsible corporate surety, authorized to issue such bonds in the State of california and secured through an authorized agent with an office in califomia.

Spec/a/ Risks or Circumstances
City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other circumstances.

Certificate Holder Address
Toe address for malling certificates, endorsements and notices shall be:

Qty of Stockton
Its Officers, Officials, Employees and Volunteers
400 E Main Street, 3rd Floor - HR
Stockton, CA 95202

Page 18 of 40 ends

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA EXHIBITC

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 1 of 14
DISCRIMINATION AND Effective Date: Revised From: HARASSMENT POLICY 7/27/09 5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 511195, 1/1198 PER-037 (Sexual Harassment Investigative Procedures) revised from 2115193 I. PURPOSE
The purpose of this policy is to reaffirm the City's commitment to demonstrating respect for all individuals by' strictly prohibiting discrimination and harassment, including sexual harassment in the workplace. This policy defines prohibited behavior and conduct, and sets forth a procedure for reporting, investigating and resolving complaints of discrimination, harassment, in the workplace, including retaliation and hostile work environment.

II. POLICY
A. The City of Stockton prohibits any form of discrimination and/or harassment of any person based on race, religious creed, color, national origin, ancestry, military and veterans status, physical or mental disability, medical condition, genetic characteristics or information, denial 6f family and medical care leave, marital status, sexual orientation, sex {including gender, gender identity, gender expression, transgender, pregnancy, childbirth and breastfeeding), political affiliation, age (40 and older),, concerted labor activity, or any other category or attribute consistent with state or federal law.

All such discrimination and harassment is unlawful and shall not be tolerated. In addition, under the federal Affordable Care Act (ACA), the City of Stockton prohibits discrimination and/or harassment, or retaliation against an employee who obtains coverage, receives·a tax credit or subsidy through the Health Care .. Market Place" or ••Exchange."
B. It is an unlawful employment practice to discriminate against or to harass an unpaid intern or volunteer on the basis of any legally protected classification unless an exception applies, such as a bona fide occupational qualification.

C. The City will neither tolerate nor condone discrimination and/or harassment of employees by managers, supervisors, co-workers, or non-employees with whom City employees have a business service, or professional relationship.

D. All City employees and non-employees share a responsibility to assist in

Page 19 of 40 ends

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA EXHIBITC

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No, 2 of 14
DISCRIMINATION AND Effective Date: Revised From: HARASSMENT POLICY 7/27/09 5/1/2015 4/6/09
3/1/2010
{see below}
PER-015 (Sexual Harassment'in the WOfkplace) re111sed from 10121194, 511195, 1/1198 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15193 maintaining an employment environment . free of discrimination and harassment. This policy applies to all aspects of City employment, including, but not limited to, hiring, reassignment, placement, promotion, employment action, disciplinary action, layoff, reemployment, transfer, leave of absence, compensation and benefits, training; or other terms of treatment of that person in an unpaid internship, or another limited duration program to provide unpaid work experience for that person, or the harassment of an unpaid intern or volunteer.

E. All allegations of discrimination and/or harassment shall be investigated immediately by the City, in accordance with this policy. If it Is determined that any prohibited activity has occurred, remedial action shall be taken. Such action may include discipline up to and including discharge. In addition, under applicable law, individual supervisors and employees may be subject to personal liability and/or punitive damages in any litigation arising as a result of such conduct.

F. All new hires shall attend harassment awareness training, and supervisors and managers shall attend harassment awareness and prevention training for supervisors every two years.

G. The City of Stockton prohibits retaliation against any employee or non­ employee by another employee, non-employee, supervisor, or manager for reporting, filing, testifying, assisting or participating in any manner in any investigation, proceeding, or hearing conducted by the employer or a federal or state enforcement agency.

H. This policy applies to all officials, employees, volunteers, unpaid interns, agents, or contractors of the City.

I. This policy shall be administered by the Director of Human Resources.

Page 20 of 40 ends

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA

EXHIBIT C

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 3 of 14
DISCRIMINATION AND Effective Date: Revised From: HARASSMENT POLICY 7/27/09 5/1/2015 4/6/09
3/1/2010
(see below)
PEA-015 (Sexual Harassment In the Wori<plac.e) revised from 10/21194, 511195, 1/1198 PER-037 (Sexual Harassment lnvestigaUve Procedures) revised from 2/15193 HI. . .DEFINITION AND EXAMPLES OF DISCRIMINATION AND HARASSMENT A. "Discrimination," as used in this policy, is any action, behavior, practice, or process that is intended to deny, or results in the denial of, employment rights, privileges, or benefits because of a person's race, religious creed, color, national origin, ancestry, military and veterans status, physical or mental disability, medical condition, genetic characteristics or information, denial of family and medical care leave, marital status, sexual orientation, sex (including gender, gender identity, gender expression, transgender, pregnancy, childbirth and breastfeeding), political affiliation, age (40 and older), concerted labor activity, or any other prohibition identified under state and federal law. The following are examples of conduct that may constitute discrimination:

1. Soliciting applications from a source where all or most of potential workers are of the same race or color.

2. Considering a person's gender as the basis for differences in pay, work assignments, performance evaluations, training, discipline, or any other area of employment; and

3. Questioning a job applicant about the existence, nature and severity of a disability.

B. "Harassment," as used in this policy, consists of any conduct affecting another person because of his or her race, religious creed, color, national origin, ancestry, military and vetert:tns status, physical or mental disability, medical condition, genetic characteristics or information, denial of family and medical care leave, marital status, sexual orientation, sex (including gender, gender identity, gender expression, transgender, pregnancy, childbirth and breastfeeding), political affiliation, age (40 and older), concerted labor activity, or any other category or attribute identified under state and federal law when such conduct has the purpose or the effect of: (1) creating an intimidating, hostile or offensive work environment; (2) unreasonably interfering with the employee's or non-employee's work performance; or (3)

Page 21 of 40 ends

EXHIBIT 2
Subject:

CITY OF STOCKTON. CALIFORNIA EXHIBirc
CITY MANAGER ADMINrSTRA TIVE DIRECTIVE
Directive No. HR-15 Page No. 4 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09
5/1/2015 4/6/09
3/1/2010
(see below) ' PER-015 (Se,cual Harassment "1 the Workplace) revtsed from 10121/94, 511/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised ftom 2115/93 otherwise adversely affecting an employee•s or non-employee's �mployment opportunities.

Harassment may take many forms. including. but not limited to, the following examples:

1. Verbal Harassment: Epithets. derogatory and offensive comments or slurs based on race. religion. color. national origin, ancestry. physical or mental disability, marital status. pregnancy. medical condition, gender. sexual orientation, political affiliation, age. or any other category or attribute identified under state and federal law.

2. e,hysicat Harassment: Assault, impeding or blocking movement that results in the physical interference \\1th normal work or movement on the basis of race, religion, color. national origin, ancestry, physical or mental disability. marital status. pregnancy, medical condition, gender, sexual orientation, political affiliation, age, or any other category or attribute identified under state and federal law.

3. Visual Harassment:. The displaying of posters, photography, notices. bulletins, e-mails, cartoons or drawings with derogatory and offensive content based on race, religion, •color, national origin, ancestry, physical or mental disability, marital status. pregnancy, medical condition, gender, sexual orientation, political affiliation, age, or any other category or attribute identified under state and federal law.

C. "Sexual harassment," as used in this policy, is a subcategory of harassment. and is specifically defined by law as unwanted sexual advances, requests for sexual favors or visual. verbal or physical conduct of a sexual nature when:

1. Submission to such conduct is made a term or condition of employment; or

2. Submission to or rejection of such conduct is used as a basis for employment decisions affecting the individual; or

Page 22 of 40 ends

EXHIBIT 2
Subject:

CtTY OF STOCKTON. CALIFORNIA EXHIBIT C

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR�15 Page No. 5 of 14
DISCRIMINATION AND Effective Date: Revised From: HARASSMENT POLICY 7/27/09 5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sell(ual Harassment In the Workplace) revised from 10121194, 5/1195, 1/1/98 PER-037 (Sell(ual Harassment lnvesligatiVe Procedures) revised from 2/15193

3. Such conduct has the purpose or effect of unreasonably interfering with an employee's or non-employee's work performance or creating an intimidating, hostile or offensive working environment because of the persistent, severe or pervasive nature of the conduct.

Examples of Sexual Harassment include, but are not limited to the following:
a. Unwelcome sexual overtures or propositions.
b. • Offering employment benefits or status in exchange for sexual favors.
c. Making or threatening retaliation after a negative response to sexual advances.
d. Visual conduct such as leering, making sexual gestures, displaying sexually suggestive objects or pictures, cartoons, calendars or posters.
e. Verbal conduct such as using epithets or slurs, telling sexually explicit jokes, or making derogatory or suggestive comments about a person's body or dress.
f. Written communications of a sexual nature distributed in hard copy, soft copy or via a computer network.
g. Verbal abuse of a sexual nature, graphic verbal commentary about an individual's body, sexually degrading words to describe an individual, suggestive or obscene letters, notes or invitations.
h. Physical conduct such as touching, assaulting, impeding or blocking movements.

Page 23 of 40 ends

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA EXHIBITC

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 6 of 14
DISCRIMINATION AND Effective Date: Revised From: HARASSMENT POLICY 7/27/09 5/1/2015 4/6/09
3/1/2010
•- (see below)
PER-015 (Sexual Harassment In the Workplace) revised from 10121/94, 5/1195, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2115/93 i. Retaliation for making harassment reports or threatening to report harassment.

D. Affordable Care Act (ACA) Anti-Reta!iati9n
Pursuant to section §1558 of the Affordable Care Act, the City prohibits discrimination or retaliation towards any employee who:

1. Receives a health insurance tax credit or subsidy through the Health Care "Marketplace., or 11Exchange", by which can trigger a penalty payable by the employer;

2. Reports potential violations of protections afforded under Title I of the Act, which provides guaranteed availability protections among other things;

3. Testifies in a proceeding concerning such violation;

4. Assists or participates in a proceeding concerning a violation; or

5. Objects to, or refuses to participate in, any activity, policy, practice, or assigned task that the employee reasonably believes to be in violation of any provision of the Title I of the Act.

An employee who believes that he or she has been discharged or otherwise discriminated against in violation of section §1558 of the Affordable Care Act may seek relief in accordance with t�e procedures, notifications, burdens of proof, remedies, and statutes of limitation set forth in section 2087(b) of title 15, United States Code.

IV. REPORTING AND COMPLAINT PROCEDURES
A. lmmediate Action Required
The City's reporting and complaint procedures provide for an immediate, thorough and objective investigation of discrimination or harassment claims, appropriate disciplinary action taken against any person found to have engaged in prohibited behavior, and appropriate alternative remedies to any

Page 24 of 40 ends

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA EXHIBIT C

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 7 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09
5/1/2015 4/6/09
3/1/2010
(see below) '· PER-015 (Sexual Harassment In the WO(kplace) reVlsed from 1°'21194, 511/95, 1/1/98 PER•037 (Sexual Harassment Investigative Procedures) revised from 2/15193 employee or non-employee subject to dlscrimin�tion or harassment. To accomplish this, such incidents must be reported immediately to a supervisor or manager.

1. Emal2vee'§ go� t)l_on:-Employee's Responsibilities when Subjected to _Discrimination and/or Harassment
a. Employees or non-employees who believe they have been subjected to discrimination or harassment, or are aware of discrimination or harassment against others, shall report the situation immediately to his/her supervisor or manager, except as specified in subsection (b), below. Employees and non­ employees shall report any such incidents occurring in the workplace, whether committed by coworkers, supervisors or managers, or third persons doing business with the City, such as customers or vendors, or other non-employees. If
comfortable doing so, an employee or non-employee who has a complaint of discrimination or harassment is encouraged to directly inform the person(s) engaging in the behavior that such conduct is offensive and insist the behavior to stop.
b. Employees and non-employees must immediately contact a supervisor or manager to register a complaint of discrimination or harassment, unless that supervisor or manager is the individual engaging in the unwanted behavior. In that case, the employee or non-employee may contact someone at the next supervisory level. If the employee or non-employee feels uncomfortable dealing directly with his or her immediate supervisor or manager, he or she may contact the department head, or the Director of Human Resources (or either of their designees) to register a complaint of discrimination or harassment.
c. Employees and non-employees may file a formal complaint of harassment or discrimination with their department head or

Page 25 of 40 ends

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA EXHIBITC

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 8 of 14
DISCRIMINATION AND Effective Date: Revised From: HARASSMENT POLICY 7/27/09

2. 5/1/2015 4/6/09
3/1/2010
(see below)
• PER·015 Sexual Harassment In lhe Work lace revlsec from 10121194 511195 1/1198 •( p l ' I PER-037 (Sexual Harassment Investigative Procedures) revised from 2115193 with Human Resources. To assi�t the City in conducting a thorough investigation, complaints shall be submitted in writing and shall include specific details of the incident(s). the names of the individuals involved, the names of any witnesses, and any documentary evidence (notes, pictures, cartoons, etc.) that will corroborate the allegations,
d. Employees and non-employees shall immediately report any retaliation to a supervisor, manager, department head or Director of Human Resources (or designee). All retaliation complaints shall be immediately, objectively and thoroughly investigated in accordance with the investigation procedures.

If a report of retaliation is substantiated, appropriate disciplinary action, up to and including discharge shall be taken.

Supervisor's or Manager's Re§Ponsibilities to Eliminate Dfscrimination and/or Harassment
a. A supervisor or manager is responsible for enforcing the City's discrimination and harassment policy. Supervisors or
managers must ensure that all employees and non-employees are aware of the City's policy through open discussion of the policy at staff meetings and by posting the policy in a conspicuous location accessible to alt staff members.
b. A supervisor or manager shall be cognizant of employees' and non-employees' behavior and shalt not permit any employee or non-employee under their supervision to be subjected to or engage in any conduct prohibited by this policy.
c. A supervisor or manager who observes conduct prohibited by this policy shall immediately direct the employee or non­ employee to cease the conduct.

Page 26 of 40 ends

EXHIBIT 2
Subject:

EXHIBITC

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 9 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER·015 (Sexual Harassment tn the Workplace) revised from 10/21194, 511/95, 1/1/98 PER.037 (Se11Ual Harassment Investigative Procedures) revised from 2115/93 d. A , supervisor or manager who receives a complaint of prohibited conduct is 'required to take the complaint seriously, and report the matter immediately to the department head; be supportive of the complainant; ensure there is no retaliation against the complainant; conduct an internal fact-finding review into the allegations; obtain as much detailed information as possible; thoroughly document the findings; communicate in written form to the parties the resolution of the complaint; and report to and consult with the Human Resources Department promptly, without delay.

8. Confidentiality. The City will make every effort to protect the privacy and confidentiality of all parties involved, as well as any information and/or documentation obtained, to the extent possible consistent with a thorough investigation.

C. Penalty for Non-Comgliance .. The City shall take disciplinary action, up to and including discharge, against any supervisor or manager who fails in his/her responsibility to take immediate action in response to an employee's or non--employee's complaint of discrimination or harassment Further, such disciplinary action shall be taken against a supervisor or manager who fails to stop discriminatory or harassing conduct committed in his/her presence or to stop such conduct about which the supervisor or manager has knowledge.

V. INVESTIGATION PROCEDURES'
A. Qe��nnination of_ Responsibility for. lnyestigation.

If a formal complaint is filed with the department head or the Director of Human Resources (or either of their designees), the department head and the Director of Human Resources shall consult with one another to determine whether the department or Human Resources shall conduct the fact-finding investigation into the allegations. Either the department head or the Director of Human Resources (or either of their designees), depending on who is

Page 27 of 40 ends

EXHIBIT 2
Subject:

B.

CITY OF STOCKTON, CALIFORNIA EXHIBiTC

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 PageNo.10 of 14
DISCRIMINATION AND Effective Date: Revised From: HARASSMENT POLICY 7/27/09 5/1/2015 4/6/09
3/1/2010
(see below) ' PER-015 (Sexual Harassment In the Wo,kplace) reY1sed ffom 10/21/94. 511195, 1/1198 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15193 responsible for the investigation, shall issue written notificatiqn to the complainant and alleged harasser(s). The notification shall specify the nature of the complaint, and inform the parties that an investigation into the allegations of discrimination and/or harassment shall be conducted.

Investigative Guidelines
The investigation shall include the following steps taken in the order best suited to the circumstances:

1. Identify and preserve the evidence.

2. Confirm the name and position of the complainant. Interview the complainant.

3. Allow the complainant the opportunity to place the complaint in writing.

4. Obtain the identity of the alleged harasser(s).

5. Obtain as many details as possible regarding the incident(s) that prompted the complaint, including the number of occurrences, dates, times, locations, and witnesses (if applicable).

6. Ascertain how the complainant felt about the alleged incident when it occurred; complainant's response(s) to the alleged behavior; and witness statements (if applicable).

7. Ascertain if any threats or promises were made in connection with the alleged harassment.

8. Ascertain if the complainant knows of or suspects that there are other victims of harassment by the same person(s).

9. Ascertain whether the complainant has spoken to anyone, especially

Page 28 of 40 ends

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA EXHIBIT C

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No.11 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual� arassment In the Workplace) revised from 10/21/94, 511/95, 1/1/98 PER-037 (Sexual Harassment lnvestigatiVe Procedures) revised from 2/15/93 supervisors, about the harassment.

10. Ascertain what resolution would be acceptable to the complainant.

11. Interview the alleged harasser to get his or her side of the story, including any possible motivation for a false allegation.

12. Interview witnesses who were identified by the complainant regarding the alleged harasser or other persons identified during the investigation.

13. Interview witnesses who were identified by the alleged harasser or other persons identified during the investigation.

14. Advise all participants that the investigation is "confidential" and not to engage ln any retaliatory conduct. as such conduct is subject to_ disciplinary action up to and including discharge. Confidentiality will be maintained to the extent possible. An individual who is interviewed during the course of an investigation is prohibited from discussing the substance of the interview, except as otherwise directed by a supervisor or the Director of Human Resources. Any individual who discusses the content of an investigatory interview will be subject to discipline or other appropriate sanction.

15. Conduct follow-up interviews. if warranted.

16. Prepare report of findings and discuss with management and designated legal staff.

VI. RESPONDING TO THE COMPLAINT
A Following the completion of the fact-finding investigation, either the department head or the Director of Human Resources ( or either of their designees), depending on who is responsible for the investigation, shall

Page 29 of 40 ends

EXHIBIT 2
Subject:

CITY OF STOCKTON, CALIFORNIA

EXHIBITC

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Oirectlv� No. HR •15 Page No.12 of 14
DISCRIMINATION AND Effective Date: Revised From: HARASSMENT POLICY 7/27/09 5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment In the Workplace) revised ftom 10/21194, 511195, 1/1198 PER-037 (Sexual Harassment lnvesClgative Procedures) revised from 2/15193 make a report of findings, along with a recommendation regarding the appropriate remedial action to be taken, If warranted. The recommendation shall be made after reviewing the findings of the investigation, giving consideration to all factual information, the nature of the alleged conduct, and the totality of the circumstances. If the investigation was conducted by the Director of Human Resources, or deslgnee, the Director, or designee, shall confer with the affected department head and both shall concur on the remedial action to be taken, if any. If the investigation was conducted by the department head, the department head shall confer with the Director of Human Resources prior to making the report of findings and both shall concur on the remedial action to be taken, if any.

B. If either the department head or the Director of Human Resources does not concur with the findings and recommendation of the other, the City Attorney (or designee) shall review and resolve the matter in dispute.

C. Report of findings and recommendation shall be treated as a confidential document and no other distribution shall be made without first consulting with the City Attorney's Office. A completed investigation report will not be disclosed, except as it is deemed necessary to support a disciplinary action, to take remedial action, to defend the City in adversarial proceedings, or to comply with the law or court order.

0. Either the department head or the Director of Human Resources (or either of their designees), depending on who is responsible for the investigation shall provide a written response to the complainant and the person alleged to have committed the misconduct, discrimination and/or harassment. The response shall include a copy of the Citts discrimination and harassment policy and a memorandum indicating the City's determination as to whether the complaint is:

1. Unsustained: The investigation failed to disclose sufficient evidence to substantiate the allegation(s).

2. Unfounded: The investigation proved that the act(s) or omission(s)

Page 30 of 40 ends

EXHIBIT 2
Subject:

EXHIBITC

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No.13 of 14
DISCRIMINATION AND Effective Date: Revised From: HARASSMENT POLICY 7/27/09 5/1/2015 4/6/09
3/1/2010
(see below)
,.

PER•015 (Sexual Ha,assment In the Workplace) revised from 10/21/94, 511/95, 1/1/98 PER·037 (Sexual Harassment Investigative Procedures) revised from 2/15193 complained of did not occur. The finding ,also applies when the individual employee(s) named in the complaint were not involved in the act(s) or omission(s) alleged.

3. Sustained: The investigation disclosed sufficient evidence to substantiate the altegation(s) made in the complaint; appropriate action will be taken.

E. Details regarding any specific fact-findings or disciplinary action to be taken will not be communicated to the complainant. The City Attorney shall review the response for legal sufficiency before dissemination.

F. The City shall close and retain the investigation file, in accordance with applicable laws, regulations, and City policy regarding retention of City records.

VII. DISCIPLINE
Disciplinary action imposed as a result of any investigation conducted pursuant to this policy shall be commensurate with the severity of the offense. up to and including discharge, even for a first offense.

VIII. ALTERNATIVE REMEDIES
If upon exhausting all internal remedies to file, investigate, and respond to a charges of discrimination/harassment, pursuant to title VII of the Federal Civil Rights Act of 1964 {42 U.S.C §§ 2000e et seq.), any person has a right to file a charge of discrimination/harassment with the Equal Employment Opportunity Commission rEEOC"). In addition, pursuant to the California Fair Employment and Housing Act (Gov. Code §§ 12900 - 12996.) a person may also file a complaint of discrimination/harassment with the California Department of Fair Employment and Housing {"DFEH"). Employees or non-employees who believe that they have been subjected to discrimination/harassment may file a complaint with either of these

Page 31 of 40 ends

EXHIBIT 2
Subject:

EXHIBITC

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR .. 16 Page No. 14 of 14
DISCRIMINATION AND Effecth,e Date: Revised From: HARASSMENT POLICY 7/27/09 6/1/2016 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment In the Workplace) revised from 10121/94, 511195, 1/1/98 PER·037 (Sexual Harassment Investigative Procedures) revised from 2/15193 agencies. Both the EEOC and DFEH serve as neutral fapt-finders and attempt to assist parties in resolving disputes voluntarily.

IX. COMMUNICATION OF POLICY.

This policy shall be provided to all managers, supervisors1 employees, volunteers, unpaid interns, agents or contractors of the City and shall be posted in the appropriate places. All empfoyees shall participate in City approved harassment awareness training as directed by management or Human Resources; and all supervisors, as required by law, shall participate in City approved interactive harassment awareness training and education sessions at least once every two years, or as otherwise specified by law.

APPROVED:
��SON

CITY MANAGER
::OOMA\GRPWISE\COS.PER.PER_lib<ary:96180, I

Page 32 of 40 ends

EXHIBIT 2
Bond No. ES00017027
Premium: $1,650
Premium is for contract term and is subject
to adjustments based on final contract price

BOND FOR FAITHFUL PERFORMANCE
KNOW ALL MEN BY THESE PRESENTS:

That we, W.C. MALONEY, LLC, a (STATE OF CALIFORNIA CORPORATION), as Principal and , .. Everest National Insurance Compan� and existing under the laws of the State of Delaware
, a corporation, organized
and duly authorized to
transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, as obligee, in the just and full sum of ONE HUNDRED FOURTEEN THOUSAND FIVE HUNDRED FIFTY AND 00/100 DOLLARS ($114,550.00), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to the said CITY, the said Principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.

The condition of the foregoing obligation is such that the above bounded Principal has simultaneously entered into a contract with the CITY, to do and perform the following work, to wit:

VAN BUSKIRK BUILDING DEMOLITION
(PROJECT NO. WP24025)
NOW, THEREFORE, if the above bounded Principal, CONTRACTOR, Company or
Corporation or its subcontractor, shall well and truly perform the work contracted to be done under said contract, then this obligation to be null and void; otherwise to remain in full force and effect.

No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract, or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY, and no forbearance on the part of the said CITY shall operate to relieve any Surety or Sureties from liability on this bond, and consent by said Surety is hereby given, and the said Surety hereby waives the

Page 33 of 40 ends

EXHIBIT 2
provided that any and all claims hereunder shall be filed and proceedings had in connection therewith as required by the provisions of Division 3, Part 4, Title 15, Chapter 5, Article 1 of the Civil Code of California, provided that in case suit is brought upon this bond, a reasonable attorney's fee shall be awarded by the Court to the prevailing party in said suit; said attorney's fee to be fixed as costs in said suit, and to be included in the judgment therein rendered.

No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY and no forbearance on the part of the said CITY shall operate to relieve any surety or sureties from liability on this bond, and consent to make such alterations without further notice to or consent by any such surety is hereby given, and the said sureties hereby waive the provisions of Sections 2819 and 2845 of the Civil Code of the State of California.

SIGNED AND SEALED on _Fe_b_ru_a_,,_ry_2-'-, 2_0_24 __________ ----:.

APPROVED AS TO SURETY:

Everest National Insurance Company
SURETY
APPROVED AS TO FORM & CONTENT:

LORI M. ASUNCION

OFFICE OF THE CITY ATTORNEY
By:---------­

DEPUTY CITY ATTORNEY

Page 34 of 40 ends

EXHIBIT 2

ACKNOWLEDGMENT
A notary public or other officer completing this
certificate verifies only the identity of the individual who signed the document to which this certificate is
attached, and not the truthfulness, accuracy, or
validity of that document.

State of California
County of _____ ::;,:.Bc:u�tte _____ .. )
On -�--F .... eb __ r __ u __ a...,ry ___ 2_.. __ 2 __ 0 __ 2 ..... 4 __ before me, ____ S"""a"""'r..a.a_W�a.;.;.lli __ s __ er..,, _N_o_ta_ry...,____P_u_b-'li--'-_c'-__ _ (insert name and title of the officer)
personally appeared Elizabeth Collodi
who proved to me on the basis of satisfactory evidence to be the person(st whose name(st is/afe subscribed to the within instrument and acknowledged to me that Re/she/tRey executed the same in R+&/her/� authorized capacity(iest, and that by M;/her/� signature(st on the instrument the person(st; or the entity upon behalf of which the person(st acted, executed the instrument.

I certify under PENAL TY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.

WITNESS my hand and official seal.

Signature 6ill-1'J ch (Seal)

Page 35 of 40 ends

EXHIBIT 2
Li. everest
rv

POWER OF ATTORNEY
EVEREST REINSURANCE COMPANY and EVEREST NATIONAL INSURANCE COMPANY KNOW ALL PERSONS BY THESE PRESENTS: That Everest Reinsurance Company and Everest Natmnal Insurance Company, corporations of the State or Delaware ("Company") having their principal offices located a1 Warren Corporate Center, 100 Everest Way, Warren, New Jersey, 07059, do hereby nominate, constitute, and appoint:

Elizabeth Collodl, John Hopkins, John J. Weber, Joseph H. Weber, Renee Ramsey, Sam Wal/Iser, Mindy Wllltehouse, Jennifer Lalcmann, Deanna Quintero, BIii Rapp, J05on March, Matthew Fosler, Tony Clarie, Kristle Phi/lips, Claudine Gordon, Michael K Fffney, Samenth11 Walkins, Phil Watlc/ns, Brad Espinosa, Paula Senna, Pam Sey, Breanna Boatright, Kalhloan Le, Sharon Smith, Casandra Medina tts true and lawful Allorney(s)-in-fad to make. execute, attest, seal and deliver for and on its behalf, as surely, and as its ad and deed, where required, any and all bonds and undertakings in the nature thereof, for the penal sum or no one of which is in any event to exceed UNLIMITED, reserving for itself lhe full power of substitution and revocation.

Such bonds and undertakings, when duly exeeuled by the aforesaid Allorney(s}-in-fad shall be binding upon the Company as fully and to the same extent as if such bonds and undertakings were signed by the President and Secretary of the Company and sealed with its corporate seal.

This Power of Attorney Is granted and ·,s signed by facsimile under and by the authority of the following Resolu1ions adopted by the Board of Directors of Company ("Soard") on April 21, 2016:

RESOL 111:D. that the Prosident, any Executive Vice Prosident, and any Senior Vice Prosident are hereby appoinlad by Iha Board as authorized to make, execute, seat and deliver for and on behalf of Iha Company, any and all bonds, undertakings, contracts or obligations in suroty or co-sunity with others and that the Secretary or any Assistant SllCl'fltary of the Company be and thar each of them hereby is authorized to attest to the execvhon of any such bonds, undertakings, oontrscts or obligations in surety or co-surety and attach therolo Iha corporate seal of Iha Company.

RESOLVED, FURTHER, that Iha President, any Executive Vice President, and any Senior Vice President ara hereby authorized to execute powers of attorney �alifying the attomey named in the given power of attomay to execute, on behalf of the Company, bonds and underlakings in surety or co-surety with othern, and that the Secratary or any AsSJs/ant Secretary of the Company be, and that each of them is hereby authorized to attest the execution of any such power ol attorney, and to attach thereto the co,porote seal of the Company
RESOLVED, FURTHER, that the signature of such office,s na1116d in the preceding rosolu�ons and /he corporate seal of the Company may be afrixad to such powern of attorney or lo any certificate rela�ng thereto by facsirrola, and any such power of attomey or certmcale bearing such facsimile signatures or facsimile seal shall be thereafter valid and bindng upon the Company with re sped to any bond, undertaking, cont rad orobliga�on in surety or co-surety with others to which ii is attached.

IN WITNESS WHEREOF. Everest Reinsurance Company and Everes1 National Insurance Company have caused their corporate seals to be affixed hereto, and these presents to be signed by their duly authorized officers this 10"' day of Octobe1 2023.

Everest Reinsurance Company and Everest National Insurance Company By: Anthony Romano, Senior Vice President
Qi this 22"" of March 2023, before me personally came Anthony Romano, known 10 me, who. being duly sworn did execute the above instrument: that t-e knows the seal a said Company, that the seal affixed 10 the aforesaid instrument IS such corporate seal and was affixed thereto: and that he executed said instrument l:r)I like order.

LINDA ROBINS
Notary Public, State ol NowYor1c
No 01R082397Je
Quallfled In a.-na County
Term Expires Aprll 26, 2027
I�
..,f_) !
ifift-- f;L-,J
Linda Robins, Notary Public
I, Sylvia Semerdjian, Assistant Secretary of Everest Reinsurance Company and Everest National Insurance Company do hereby certify that I have compared the foregoing copy cf the Power of Attorney and affidavit, and the copy a the Seciion of the bylaws and resolutions of said Corporation as set forth in said Power of Attorney, with the ORIGINALS ON FILE IN THE HOME OFFICE OF SAID CORPORATION, and that the same are correct transcsipts thereof, and c:I the whole of the said originals, and that the sa·1d Power of Attorney has not been revoked and is now in full force and effect.

IN WITNESS WHEREOF, I have hereunto set my hand and affixed the seal of said Company, this.Zilll. day of,February 202�- II �.
,.,
EAL
,as
w� ___ .,,,
• By: Sylvia Semerdjian, Assistant Setfetary
ES 00 01 04 16 Page 36 of 40
EXHIBIT 2
Bond No. ES00017027
Premium is included in Performance Bond

BOND FOR LABOR AND MATERIAL
KNOW ALL MEN BY THESE PRESENTS:

That we, W.C. MALONEY, LLC, a (STATE OF CALIFORNIA CORPORATION), as Principal and Everest National Insurance Comeant corporation, organized and existing under the laws of the State of Delaware and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, and unto any and all material suppliers, persons, companies, or corporations furnishing materials, provisions, provender or other supplies used in, upon, for or about the performance of the work contemplated to be executed or performed under the contract hereinafter mentioned, and all persons, companies, or corporations renting or hiring teams, or implements of machinery, for or contributing to said work and all persons who perform work or labor upon the same, and all persons who supply both work and materials, and whose claims have not been paid by the contractor, company or corporation in the just and full sum of ONE HUNDRED FOURTEEN THOUSAND FIVE HUNDRED FIFTY AND 00/100 DOLLARS ($114,550.00), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to said CITY and to said persons jointly and severally, the said principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.

The condition of the foregoing obligations is such that the above bounden Principal has simultaneously entered into a contract of even date herewith, with the CITY, to do and perform the following work, to-wit:

VAN BUSKIRK BUILDING DEMOLITION
(PROJECT NO. WP24025)
NOW, THEREFORE, if the above bounden Principal, CONTRACTOR, Company or Corporation or its subcontractor, fail to pay for all materials, provisions, provender, or other supplies, or teams, used in, upon, for or about the performance of the work contracted to be done, or for any work or labor done thereon of any kind, the Surety on this bond will pay the same, in an amount not exceeding the sum specified in this bond,

Page 37 of 40 ends

EXHIBIT 2
EXHIBIT 2
EXHIBIT 2
EXHIBIT 2

← All documents from this meeting