CONSTRUCTION CONTRACT
FOR ELECTRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 This contract is made and entered into on _____________, by and between HOWK SYSTEMS, INC. a STATE OF CALIFORNIA CORPORATION , with a business address at 1825 YOSEMITE BLVD MODESTO, CA 95354 , hereinafter called "CONTRACTOR," and CITY OF STOCKTON, a municipal corporation, hereinafter called "CITY."
W I T N E S S E T H:
WHEREAS, plans and specifications
for the construction of ELECTRICAL UPGRADES OF
WATER WELLS NO. SSS #3 AND SSS #9 (PROJECT NO. UH22004) , hereinafter called “PROJECT,” were regularly adopted by Council Resolution No. __________________, on _________________; and WHEREAS, the contract for said work was regularly awarded to CONTRACTOR, by Council Resolution No. __________________, on ________________.
NOW, THEREFORE , in consideration of the promises and of the mutual covenants herein contained, the parties hereto expressly agree as follows:
CONTRACTOR agrees:
1. SCOPE OF SERVICES. To do the work and furnish all the labor, material s, tools, equipment, and insurance required for the construction of PROJECT in accordance with the plans and specifications adopted on _____________, by Council Resolution No. __________________ . The "contract documents," which include the bid document s, project plans, specific ations, all letters of clarification, and the City of Stockton Standard Specifications and Plans, are incorporated into and made a part of this contract by this reference to the same extent as if fully set forth.
2. COMPENSATION. To do and perform the work contemplated hereby in a good and workmanlike manner and to furnish all labor, material s, tools, and equipment nece ssary therefore at the prices specified in Exhibit A, attached hereto and by reference made a part hereof, under the direction of and to the complete satisfaction of the Director of M unicipal Utilities department of the City of Stockton.
Total compensation for services and reimbursement fo r costs shall not exceed $754,717, or as otherwise mutually agreed to in a Contract Change Order.
3. INSURANCE. CONTRACTOR shall not commence any work before obtaining, and shall maintain in force at all times during the duration and performance of this contract, the policies of insurance specified in Exhibit B, which is attached to this contract and incorporated by this reference, and as provided in the “contract documents” including Section 7-1.06 of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27, effective September 27, 2016.
It shall be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be available to the Additional Insured.
Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any insurance policy or proceeds available to the named Insured; whichever is greater.
The Additional Insured coverage under the CONTRACTOR’s policy shall be “primary and non-contributory” and will not seek contribution from the City of Stockt on’s insurance or self-insurance and shall be at least as broad as ISO CG 20 01 04 13.
The limits of insurance required in this agreement may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis for the benefit of the City of Stockton (if agreed to in a written contract or agreement) before the City of Stockton’s own insurance or self-insurance shall be called upon to protect it as a named insured.
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
All self-insured retentions (SIR) must be disclosed to the CITY’s Risk Management for approval and shall not reduce the limits of liability. Payment Bond in th e amount of the self-insur ed retention (SIR) may be required.
Policies containing any self-insured retention (SIR) provision shall provide or be endorsed to provide that the SIR may be satisfied by either the named insured or the CITY.
The CITY reserves the right to obtain a full certified copy of any insurance policy and endorsements.
Failure to exercise this right shall not constitute a waiver of right to exercise later.
CONTRACTOR shall maintain insurance as required by this contract to the fullest amount allowed by law and shall maintain insurance for a minimum of five years following the completion of this project. In the event contractor fails to obtain or maintain completed operations coverage as required by this agreement, the City at its sole discretion may purchase the coverage required and the cost will be paid by contractor.
CONTRACTOR agrees to include with all Subcontractors in their subcontract the same requirements and provisions of this agreement including the indemnity and insurance requirements to the extent they apply to the scope of the Subcontractor’s work. Subcontractors hired by CONTRACTOR agree to be bound to CONTRACTOR and the CITY in the same manner and to the same extent as CONTRACTOR is bound to the CITY under the Contract Document s. Subcontractor further agrees to include these same provisions with any Sub-subcontractor. A copy of the CITY Co ntract Document Indemnity and Insurance provisions will be furnished to the Subcontractor upon request. The General CONTRACTOR shall require all sub- contractors to provide a valid certificate of in surance and the required endorsements included in the agreement prior to commencement of any work and contractor will provide proof of compliance to the City.
4. INDEMNITY AND HOLD HARMLESS. To the fullest extent perm itted by law, Contractor shall hold harmless, defend, and indemnify City of Stockton and its officers, officials, employees, and volunteers from and against all claims, damages, losses, and expenses including attorney fees arising out of the performance of the work described herein, caused in whole or in part by any negligent act or omission of the Contractor, any subcontractor, anyone directly or indirectly employed by any of them, or anyone for whose acts any of them may be liable, except where caused by the active negligence, sole negligence, or willful misconduct of the City of Stockton. This obligation is independent of, and shall not in any way be limited by, the minimum Insurance obligations contained in this agreement. These obligations shall survive the completion or termination of this agreement.
5. STANDARD PLANS AND SPECIFICATIONS. The performance of said wo rk and the furnishing of said materials shall be executed in accordance with Section 8-1.04B of the City of Stockton Standard Specifications and Plans as adopted on S eptember 27, 2016, by Council Resolution No. 2016- 09-27-1213, effective September 27, 2016, and the provisions of the issued project specifications.
The Director of Municipal Utilities department will furnish CONTRACTOR a weekly statement showing the number of days charged to the contract for the preceding week, the number of days specified for completion of the contract, and the number of days remaining to complete the contract. CONTRACTOR will be allowed one (1) week in which to file a written protest setting forth in what respects said weekly statement is incorrect, otherwise the statement shall be deemed to have been accepted by CONTRACTOR as correct.
6. WORKING DAYS. It is agreed by the parties to the contract that in case all the work called for under the contract in all parts and requirements, is not finished or completed within the number of days as set forth, damage will be sustained by the CITY, and that it is and will be impracticable and extremely difficult to ascertain the actual damage which CITY will sustain in the event of and by reason of such delay; and it is therefore agreed that CONTRACTOR will pay to CITY the sum of ONE THOUSAND AND NO/100 DOLLARS ($1,000) per day for each and every calendar day's delay in finishing the work in excess of the number of days prescribed; and CONTRACTOR agrees to pay said liquidated damages as herein provided, and in case the same are not paid, agrees that CITY, may deduct the amount thereof from any monies due or that may become due CONTRACTOR under the contract.
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
It is further agreed that in case the work called for u nder the contract is not finished and completed in all parts and requirements within the number of days as sp ecified, the CITY shall have the right to increase the number of days or not, as may seem best to serve the interest of CITY, and if the CITY decides to increase the said number of days, the CITY shall further have the right to charge to CONTRACTOR, CONTRACTOR's heirs, assigns or sureties, and to deduct from the final payment for the work, all or any part, as may be deemed proper, the liquidated damages as specified or the actual cost of engineering, inspection, superintendence, and other overhead expenses which are directly chargeable to the contract, and which accrue during the period of such extension, whichever is greater, except the cost of final surveys and preparation of final estimate shall not be included in such charges.
A working day shall not include, nor shall CONTRA CTOR be assessed with liquidated damages nor the additional cost of engineering and inspection during any delay beyond the time named for the completion of the work caused by acts of God or of the public enemy, acts of CITY, fire, floods, epidemics, quarantine restrictions, strikes, and freight embargoes and subject to approval by the Director of Municipal Utilities department, inability to get materials ordered by CONTRACTOR or subcontractor due to such causes provided that CONTRACTOR shall not ify the Director of Municipal Utilit ies department in writing of the causes of delay within five (5) working days from th e beginning of any such delay, and the Director shall ascertain the facts and the extent of the delay, and Director's findings of the facts thereon shall be final and conclusive.
If CONTRACTOR is delayed by reason of alterations made in these specifications, or by any act of the Director of Municipal Utilities depart ment or of the CITY, not contemplated by the contract, the time of completion shall be extended proportionately and CONTRACTOR shall be relieved during the period of such extension of any claim for liquidated damages, engineering or inspection charges or other penalties.
CONTRACTOR shall have no claim for any other compensation for any such delay.
7. CONFORMANCE TO APPLICABLE LAWS. Contractor shall comply with all applicable Federal, State, and Municipal laws, rules, and ordi nances. Contractor shall not discriminate in the employment of persons or in the provision of serv ices under this Contract on the basis of any legally protected classification, including race, color, national origin, ancestry, sex or religion of such person. a. TITLE VI
Title VI of the Civil Rights Act of 1964 requires th
at “no person in the United States shall,
on the grounds of race, color, or national origin, be excluded from participation in, be denied the benefits of, or be subjected to discrimination under any program or activity receiving federal financial assistance.” (42 USC Section 2000d ) http://www.dol.gov/oasam/regs/statutes/titlevi.htm.
The City of Stockton requires complian c
e with the requirements of Title VI in all of its
programs and activities regardless of funding source.
b. DISCRIMINATION AND HARASSMENT POLICY
The City of Stockton has a Discrimination and Harassment Policy (Exhibit C). The purp ose
of this policy is to reaffirm the CITY’s commitment to demonstrating respect for all individuals by strictly prohibiting discri mination and harassment, including sexu al harassment in the workplace, to define the types of behavior and conduct prohibited by this policy, and to set forth a procedure fo r reporting, investigating, and resolving complaints of discrimination and harassment in the workplace. c. LABOR STANDARDS PROVISIONS/CALIFORNIA LABOR CODE
The bidder shall understand that conditions set forth in Division 2, Part 7, Chapter 1, Article 2, Wage
s of the California Labor Code shall be considered part of the contract agreement. https://leginfo.legislature.ca.gov/faces/codes_displayText.xhtml?lawCode=LAB&division=
2.&title=&part=7.&chapter=1.&article=2.
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
d. PREVAILING WAGE
CONTRACTOR and
any subcontractor shall pay each employee engaged in the trade or occupation not less than the prevailing hourly wage rate. In accordance with the provisions of Section 1770 of the Labor Co de, the Director of Department of Industrial Relations of the State of California has determined the general prevailing wage and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for in Section 1773.1, apprenticeship or other training programs authorized by Section 3093 and similar purposes applicable to the work to be done. CONTRACTOR performing the work under this contract shall obtain a co py of the wage rate determination and shall distribute copies to each subcontractor. As the wage determination for each craft reflects an expiration date, it shall be the prime CONTRACTOR and each subcontractor's responsibility to ensure that the prevailing wage rates of concern is current and paid to the employee.
i. The CONTRACTOR performing the work shall be responsible for obtaining a copy of the State wage rate determination. State wage rates may be obtained at http://www.dir.ca.gov/OPRL/pwd/Determinations/Northern/Northern.pdf. The CONTRACTOR shall be responsible for po sting said wage rates at a prominent location at the work site and shall maintain same in a good readable condition for the duration of the work.
ii. Should the CONTRACTOR choose to work on a Saturday, Sunday or on a holiday recognized by the Labor Unions, the CONTRACTOR shall reimburse the CITY the actual cost of engineering, inspection, superintendence, and or other overhead expenses which are directly chargeable to the contract. Should such work be undertaken at the request of the CITY, reimbursement w ill not be required. To conform strictly with the provisions of Divisi on 2, Part 7, Chapter 1, Article 2, of the Labor Code of the State of California. To forfeit as a penalty to CITY the sum of TWENTY-FIVE AND NO/100 DOLLARS ($25.00) for each laborer, worker, or mechanic employed by CONTRACTOR, or by any subcontractor under CONTRACTOR, in the execution of this contract, for each calendar day during which any laborer, worker, or mechanic is required or permitted to work more than eight (8) hours and who is not paid the general prevailing rate of per diem wages for holi day and overtime work in violation of the provisions of Sections 1770 to 1781 of the Labor Code of the State of California. That all sums forfeited under the provisions of the foregoing sections shall be deducted from the payments to be made under the terms of this contract.
iii. The CONTRACTOR to whom the contract is awarded shall insure that the prime and each subcontractor will in accordance with Section 1776 of the Labor Code, maintain certified payroll records. A copy of said records shall be provided with each invoice to the Municipal Utilities department, Attention Contract Compliance Officer. It shall be the CONTRACTOR’S responsibility to obtain copies of the current prevailing wage rate determination for all subcontractors. Additionally, certified payroll records must be uploaded to the DIR website as required by labor code. iv. The CONTRACTOR shall comply with the provisions established in Section 1777.5 of the Labor Code concerning the 1) certified approval by local joint apprenticeship committees for the employment and training of apprentices, and 2) contribution of funds to administer and conduct apprenticeship programs, if applicable to the job. e. LOCAL EMPLOYMENT ORDINANCE
For contracts valued at $10
0,000 and above, pursuant to Stockton Municipal Code Section
3.68.095 the CONTRACTOR and a ll subcontractors shall make a good faith effort to EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
employ at least 50 percent of the workforce on this project from local residents, as measured by total labor work hours. Failure of any CONTRACTOR or subcontractor to comply with these requirements shall be deemed a material breach of the contract or subcontract. CONTRACTORS and subcontractors shall maintain records necessary for monitoring their compliance with section 3.68.095.
f. COMMUNITY WORKFORCE TRAINING AGREEMENT
For contracts valued at 1,000,000 and
above, pursuant to the implementation of the
Community Workforce Training Agreement (CWTA) adopted by the City Council on July 26, 2016, the successful bidder shall be requir ed to comply with the provisions of the CWTA. For any project subject to this Agreement, the Local Hire, Priority Apprentice and Workforce Development Program requirements shall apply in lieu of the requirem ents of Stockton Municipal Code Section 3.68.095 and no separate compliance with Section
3.68.095 will be required of the Contractors/Employers working on the project. g. SANCTIONS
Deliverables must conform with all applicabl e federal, state, and local laws. Such conformity includes compliance with federal sanctions, and Contractor Certifies that it has not and will not engage in prohibited transactions with sanctioned persons or entities.
CITY agrees:
8. COMPENSATION. To pay CONTRACTOR for the work herein contemplated in the following manner: Progress payments will be made on or about the first day of each calendar month, in such sum as shall make the aggregate of payment up to such day equal to ninety-five percent (95%) of the proportional contract price, upon the basis of the progress cert ificate of the Director of Municipal Utilities department as to the amount of work done and the proportional amount of the contract price represented therefore; and all of the remaining part of the contract price not as aforesaid paid, shall be paid at the expiration of thirty-five (35) days from the completion of said work of construction and the certification by the Director of Municipal Utilities department of such completion.
9. SECURITIES. Pursuant to Section 22300 of the Public Contract Code, CONTRACTOR will be permitted, at its request and sole expense, to substitute securities for any monies withheld by the CITY to ensure performance under the contract. Said securities will be deposited either with the CITY or with a State or federally chartered bank as escrow agent. Securities eligible for this substitution are those listed in Section 16430 of the California Government Code or bank or savings and loan certificates of deposit.
CONTRACTOR shall be the beneficial owner of any secu rities substituted for monies withheld and shall receive any interest thereon.
10. CHANGE ORDERS. CITY reserves the right to make such alterations, deviatio ns, additions to or omissions from the plans and specifications, including the right to increase or decrease the quantity of any item or portion of the work, as may be deemed by the Engineer to be necessary or advisable and to require such extra work as may be determined by the Engineer to be required for the proper completion or construction of the whole work contemplated.
Any such changes will be set forth in a contract cha nge order which will specify, in addition to the work done in connection with the change made, adjustment of contract time, if any, and the basis of compensation for such work. A contract change order will not become effective until approved by the City Manager and/or the City Council.
Processing of change orders shall be in accordance with Section 4-1.05A of the City of Stockton Standard Specifications and Plans as adopted by Council on September 27, 2016, by Resolution No. 2016-09-27- 1213, effective September 27, 2016, or as otherwise amended by Council. When the compensation for an item of work is subject to adjustment under the provisions of Standard Specifications and Plans, Section 4-
1.05A, CONTRACTOR shall, upon request, promptly furnish the Engineer with adequate detailed cost data for such item of work.
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
Exhibit B:
Insurance Requirements for Construction Contracts
()
Cont
ractor shall procure and maintain for the duration of the contract, and for 5 years thereafter, insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his agents, representatives, employees, or subcontractors.
MINIMUM SC
OPE AND LIMIT OF INSURANCE
Cov
erage shall be at least as broad as:
1. Commerc
ial General Liability (CGL): Insurance Services Office (ISO) Form CG 00 01 covering CGL on an “occurrence” basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $2,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit.
2. Aut
omobile Liability: Insurance Services Office Form CA 0001 covering Code 1 (any auto), with limits no less than $2,000,000 per accident for bodily injury and property damage.
3. Work
ers’ Compensation insurance as required by the State of California, with Statutory Limits, and Employers’ Liability insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.
4. Suret
y Bonds as described below.
If t
he contractor maintains broader coverage and/or higher limits than the minimums shown above, the City of Stockton requires and shall be entitled to the broader coverage and/or the higher limits maintained by the contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City of Stockton.
Self-I
nsured Retentions
Sel
f-insured retentions must be declared to and approved by the City of Stockton. The City of Stockton may require the Contractor to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention. The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
either the named insured or City of Stockton. The CGL and any policies, including Excess liability policies, may not be subject to a self-insured retention (SIR) or deductible that exceeds $25,000 unless approved in writing by City of Stockton. Any and all deductibles and SIRs shall be the sole responsibility of Contractor or subcontractor who procured such insurance and shall not apply to the Indemnified Additional Insured Parties. City of Stockton may deduct from any amounts otherwise due Contractor to fund the SIR/deductible. Policies shall NOT contain any self-insured retention (SIR) provision that limits the satisfaction of the SIR to the Named Insured.
The policy must also provide that Defense costs, including the Allocated Loss Adjustment Expenses, will satisfy the SIR or deductible. City of Stockton reserves the right to obtain a copy of any policies and endorsements for verification.
Other Insurance Provisions
The insurance policies are to contain, or be endorsed to contain, the following provisions:
1. The Ci
ty of Stockton , its officers, officials, employees, and volunteers are to be covered as additional insureds on the CGL policy with respect to liability arising out of work or operations performed by or on behalf of the Contractor including materials, parts, or equipment furnished in connection with such work or operations and automobiles owned, leased, hired, or borrowed by or on behalf of the Contractor.
General liability coverage can be provided in the form of an endorsement to the Contractor’s insurance (at least as broad as ISO Form CG 20 10 11 85 or both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 forms if later revisions used).
Additional insured Name of Organization shall read “City of Stockton, its officers, officials, employees, and volunteers.” Policy shall cover City of Stockton, its officers, officials, employees, and volunteers for all locations work is done under this contract.
2. For any claims related to this project, the Contractor’s insurance coverage shall be primary and non-contributory insurance coverage at least as broad as ISO CG 20 01 04 13 as respects the City of Stockton, its officers, officials, employees, and volunteers. Any insurance or self-insurance maintained by the City of Stockton, its officers, officials, employees, or volunteers shall be excess of the Contractor’s insurance and shall not contribute with it. This requirement shall also apply to any Excess or Umbrella liability policies. The City of Stockton does not accept endorsements limiting the Contractor’s insurance coverage to the sole negligence of the Named Insured.
3. Each insurance policy required by this clause shall provide that coverage shall not be canceled, except with notice to the City of Stockton.
Claims Made Policies (Professional & Pollution only)
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
If any coverage required is written on a claims-made coverage form:
1. The retroactive date must be shown, and this date must be before the execution date of the contract or the beginning of contract work.
2. Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of contract work.
3. If coverage is cancelled or non-renewed, and not replaced with another claims-made policy form with a retroactive date prior to the contract effective, or start of work date, the Contractor must purchase extended reporting period coverage for a minimum of five (5) years after completion of contract work.
4. A copy of the claims reporting requirements must be submitted to the City of Stockton for review.
5. If the services involve lead-based paint or asbestos identification/remediation, the Contractors Pollution Liability policy shall not contain lead-based paint or asbestos exclusions. If the services involve mold identification/remediation, the Contractors Pollution Liability policy shall not contain a mold exclusion, and the definition of Pollution shall include microbial matter, including mold.
Umbrella or Excess Policies
The Contractor may use Umbrella or Excess Policies to provide the liability limits as required in this agreement. This form of insurance will be acceptable provided that all of the Primary and Umbrella or Excess Policies shall provide all of the insurance coverages herein required, including, but not limited to, primary and non-contributory, additional insured, Self-Insured Retentions (SIRs), indemnity, and defense requirements. The Umbrella or Excess policies shall be provided on a true “following form” or broader coverage basis, with coverage at least as broad as provided on the underlying Commercial General Liability insurance. No insurance policies maintained by the Additional Insureds, whether primary or excess, and which also apply to a loss covered hereunder, shall be called upon to contribute to a loss until the Contractor’s primary and excess liability policies are exhausted.
Acceptability of Insurers
Insurance is to be placed with insurers authorized to conduct business in the state with a current A.M. Best rating of no less than A: VII, unless otherwise acceptable to the City of Stockton.
Waiver of Subrogation
Contractor hereby agrees to waive rights of subrogation which any insurer of Contractor may acquire from Contractor by virtue of the payment of any loss.
Contractor agrees to obtain any endorsement that may be necessary to affect this EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
waiver of subrogation. The Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of the City of Stockton for all work performed by the Contractor, its employees, agents and subcontractors.
Verification of Coverage
Contractor shall furnish the City of Stockton with original certificates and amendatory endorsements or copies of the applicable policy language effecting coverage required by this clause and a copy of the Declarations and Endorsements Pages of the CGL and any Excess policies listing all policy endorsements. All certificates and endorsements and copies of the Declarations & Endorsements pages are to be received and approved by the City of Stockton before work commences. However, failure to obtain the required documents prior to the work beginning shall not waive the Contractor’s obligation to provide them. The City of Stockton reserves the right to require complete, certified copies of all required insurance policies, including endorsements required by these specifications, at any time. City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances.
Subcontractors
Contractor shall require and verify that all subcontractors maintain insurance meeting all requirements stated herein, and Contractor shall ensure that City of Stockton is an additional insured on insurance required from subcontractors. For CGL coverage, subcontractors shall provide coverage with a form at least as broad as CG 20 38 04 13.
Duration of Coverage
CGL & Excess liability policies for any construction related work, including, but not limited to, maintenance, service, or repair work, shall continue coverage for a minimum of 5 years for Completed Operations liability coverage. Such Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of the contract of work .
Surety Bonds
Contractor shall provide the following Surety Bonds:
1. Bid Bond
2. Performance Bond
3. Payment Bond
4. Maintenance Bond
The Payment Bond and the Performance Bond shall be in a sum equal to the contract price. If the Performance Bond provides for a one-year warranty a separate EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
Maintenance Bond is not necessary. If the warranty period specified in the contract is for longer than one year a Maintenance Bond equal to 10% of the contract price is required. Bonds shall be duly executed by a responsible corporate surety, authorized to issue such bonds in the State of California and secured through an authorized agent with an office in California.
Special Risks or Circumstances
City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other circumstances.
Certificate Holder Address
The address for mailing certificates, endorsements and notices shall be:
City of Stockton
Its Officers, Officials, Employees and Volunteers
400 E Main Street, 3rd Floor – HR
Stockton, CA 95202
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
(;+,%,7&
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
BOND FOR FAITHFUL PERFORMANCE
KNOW ALL MEN BY THESE PRESENTS:
That we, _______________________________, a STATE OF CALIFORNIA CORPORATION, as Principal and , a
corporation, organized and existing under the laws of the State of and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, as obligee, in the just and full sum of SEVEN HUNDRED FIFTY-FOUR THOUSAND, SEVEN HUNDRED SEVENTEEN AND NO/100 DOLLARS ($7 54,717), in lawf ul money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to the said CITY, the said Principal and Sure ty bind themselves, thei r successors and assigns, jointly and severally, firmly by these presents.
The condition of the foregoing obligation is such that the above bounded Principal has simultaneously entered into a contract with the CITY, to do and perform the following work, to wit:
ELECTRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 (PROJECT NO. UH22004)
NOW, THEREFORE, if the above bounded Principal, CONTRACTOR, Company or Corporation or its subcontractor, shall well and truly perform the work contracted to be done under said contract, then this obligation to be null and void; otherwise to remain in full force and effect.
No prepayment or delay in payment and no change, ex tension, addition or alteration of any provision of said contract, or in said plans or specifications agreed to between the said CONTRACTOR and the said EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
CITY, and no forbearance on the part of the said CITY shall operate to relieve any Surety or Sureties from liability on this bond, and consent by said Surety is hereby given, and the said Surety hereby waives the provisions of Sections 2819 and 2845 of the Civil Code of the State of California.
SIGNED AND SEALED on
APPROVED AS TO SURETY: By:
P R I N C I P A L
S U R E T Y
APPROVED AS TO FORM & CONTENT:
LORI ASUNCION
OFFICE OF THE CITY ATTORNEY
B y :
A T T O R N E Y - I N - F A C T
B y :
ASSISTANT CITY ATTORNEY
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
BOND FOR LABOR AND MATERIAL
KNOW ALL MEN BY THESE PRESENTS:
That we, HOWK SYSTEMS, INC. a STATE OF CALIFORNIA CORPORATION, as Principal and , corporation, organized and exis ting under the laws of the State of and duly authorized to transact business unde r the laws of the St ate of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the Stat e of California, and unto any and all material suppliers, persons, companies, or corporations furnishing materials, provisions, provender or other supplies used in, upon, for or about the performance of the work cont emplated to be executed or performed under the contract hereinafter mentioned, and all persons, compani es, or corporations renting or hiring teams, or implements of machinery, for or contributing to said work and all persons who perform work or labor upon the same, and all persons who supply both work and materials, and whose claims have not been paid by the contractor, company or co rporation in the just and full sum of SEVEN HUNDRED FIFTY-FOUR THOUSAND, SEVEN HUNDRED SEVENTEEN AND NO/100 DOLLARS ($7 54,717), in lawf ul money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to said CITY and to said persons jointly and severally, the said principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.
The condition of the foregoing obligations is such that the above bounden Principal has simultaneously entered into a contract of even date herewith, with the CITY, to do and perform the following work, to-wit:
ELECTRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 (PROJECT NO. UH22004)
NOW, THEREFORE, if the above bounden Pr incipal, CONTRACTOR, Company or Corporation or its subcontractor, fail to pay for all materials, provisi ons, provender, or other supplies, or teams, used in, upon, for or about the performance of the work contracted to be done, or for any work or labor done thereon of any kind, the Surety on this bond will pay the same, in an amount not exceeding the sum specified in this bond, provided that any and all claims hereunder shall be filed and proceedings had in connection therewith as required by the provisions of Division 3, Part 4, Title 15, Chapter 5, Article 1 of the Civil Code of California, provided that in case suit is brought upon this bond, a reasonable attorney's fee shall be awarded by the Court to the prevailing party in said suit; said attorney's fee to be fixed as costs in said suit, and to be included in the judgment therein rendered.
No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY and no forbearance on the part of the said CITY shall operate to relieve any surety or sureties from liability on this bond, and consent to make such alterations without further notice to or consent by any EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004
such surety is hereby given, and the said sureties hereby waive the provisions of Sections 2819 and 2845 of the Civil Code of the State of California.
SIGNED AND SEALED on .
APPROVED AS TO SURETY: By:
P R I N C I P A L
S U R E T Y
APPROVED AS TO FORM & CONTENT:
LORI ASUNC
ION
OFFICE OF THE CITY ATTORNEY
By :
A T T O R N E Y - I N - F A C T
B y :
ASSISTANT CITY ATTORNEY
EXHIBIT 1
ELETRICAL UPGRADES OF WATER WELLS NO. SSS #3 AND SSS #9 PROJECT NO. UH22004