CONSTRUCTIO
N CONTRACT
This contr
act is made and entered into on , by and between VALENTINE CORPORATION, a STATE OF CALIFORNIA CORPORATION, with a business address at 111 PELICAN WAY, SAN RAFAEL, CA 94901 , hereinafter called "CONTRACTOR," and CITY OF STOCKTON, a municipal corporation, hereinafter called "CITY."
W I T N E S
S E T H:
WHEREAS, plans
and specifications for the construction of EL DORADO STREET BRIDGE OVER BIANCHI, PROJECT NO. WT22002, hereinafter called “PROJECT,” were regularly adopted by Council Resolution No. , on ; and
WHEREAS, the contract for said work was regularly awarded to CONTRACTOR, by Council R
esolution No. , on .
NOW, THERE
FORE, in consideration of the promises and of the mutual covenants herein contained, the parties hereto expressly agree as follows:
CONTRACTOR agrees:
1. SCOPE OF SER
VICES. To do the work and furnish all the labor, materials, tools, equipment, and insurance required for the construction of PROJECT in accordance with the plans and specifications adopted on , by Council Resolution No. . The "contract documents," which include the bid documents, project plans, specifications, all letters of clarification, and the City of Stockton Standard Specifications and Plans, are incorporated into and made a part of this contract by this reference to the same extent as if fully set forth.
2. COMPENSAT
ION. To do and perform the work contemplated hereby in a good and workmanlike manner and to furnish all labor, materials, tools , and equipment necessary therefore at the prices specified in Exhibit A, attached hereto and by reference made a part hereof, under the direction of and to the complete satisfaction of the Director of Public Works of the City of Stockton. Total compensation for services and reimbursement for costs shall not exceed $127,369.00, or as otherwise mutually agreed to in a Contract Change Order.
3. INSURANCE. C
ONTRACTOR shall not commence any work before
obtaining, and shall maintain in force at all times during the duration and performance of this contract, the policies of insurance specified in Exhibit B, which is attached to this contract and incorporated by this reference, and as provided in the “contract documents” including Section 7- 1.06 of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27-1213, effective September 27, 2016.
EXHIBIT 2
Local Construction Contract – VALENTINE CORPORATION – PROJECT NO. WT22002 (Updated 10/18/23) It shall
be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum i nsurance coverage requirements and/or limits shall be available to the Additional Insured.
Furtherm
ore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any i nsurance policy or proceeds available to the named Insured; whichever is greater.
The Addit
ional Insured coverage under the CONTRACTOR’s policy shall be “primary and non-contributory” and will not seek contribution from the City of Stockton’s insurance or self-insurance and shall be at least as broad as ISO CG 20 01 04 13.
The limi
ts of insurance required in this agreement may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess i nsurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis for the benefit of the City of Stockton (if agreed to in a written contract or agreement) before the City of Stockton’s own insurance or self - insurance shall be called upon to protect it as a named insured.
All self-ins
ured retentions (SIR) must be disclosed to the CITY’s Risk Management for approval and shall not reduce the limits of liability. Payment Bond in the amount of the self-insured retention (SIR) may be required.
Polici
es containing any self-insured retention (SIR) provision shall provide or be endorsed to provide that the SIR may be satisfied by either the named insured or the CITY.
The CITY res
erves the right to obtain a full certified copy of any i nsurance policy and endorsements.
Failure t
o exercise this right shall not constitute a waiver of right to exercise later.
CONTRACTO
R shall maintain insurance as required by this contract to the fullest amount allowed by law and shall maintain insurance for a minimum of five years following the completion of this project. In the event contractor fails to obtain or maintain completed operations coverage as required by this agreement, the City at its sole discretion may purchase the coverage required and the cost will be paid by contractor.
CONTRACTO
R agrees to include with all Subcontractors in their subcontract the same requirements and provisions of this agreement including the indemnity and insurance requirements to the extent they apply to the scope of the Subcontractor’s work.
Subcontractors hired by CONTRACTOR agree to be bound to CONTRACTOR and the CITY in the same manner and to the same extent as CONTRACTOR is bound to the CITY under the Contract Documents. Subcontractor further agrees to include these same provisions with any Sub-subcontractor. A copy of the CITY Contract Document Indemnity and Insurance provisions will be furnished to the Subcontractor upon request. The General CONTRACTOR shall require all sub-contractors to provide a valid certificate of EXHIBIT 2
Local Construction Contract – VALENTINE CORPORATION – PROJECT NO. WT22002 (Updated 10/18/23) insurance
and the required endorsements included in the agreement prior to commencement of any work and contractor will provide proof of compliance to the City.
4. INDEMNI
TY AND HOLD HARMLESS. To the fullest extent permitted by law, Contractor shall hold harmless, defend, and indemnify City of Stockton and its officers, officials, employees, and volunteers from and against all claims, damages, losses, and expenses including attorney fees arising out of the performance of the work described herein, caused in whole or in part by any negligent act or omission of the Contractor, any subcontractor, anyone directly or indirectly employed by any of them, or anyone for whose acts any of them may be liable, except where caused by the active negligence, sole negligence, or willful misconduct of the City of Stockton. This obligation is independent of, and shall not in any way be limited by, the minimum Insurance obligations contained in this agreement. These obligations shall survive the completion or termination of this agreement.
5. STANDARD
PLANS AND SPECIFICATIONS. The performance of said
work and the furnishing of said materials shall be executed in accordance with Section 8-
1.04B of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, b y Council Resolution No. 2016- 09-27-1213, effective September 27, 2016, and the provisions of the issued project specifications.
The Direc
tor of Public Works will furnish CONTRACTOR a weekly statement showing the number of days charged to the contract for the preceding week, the number of days specified for completion of the contract, and the number of days remaining to complete the contract. CONTRACTOR will be allowed one (1) week in which to file a written protest setting forth in what respects said weekly statement is incorrect, otherwise the statement shall be deemed to have been accepted by CONTRACTOR as correct.
6. WORKING DAYS
. This work shall be diligently prosecuted to completion before the expiration of 60 WORKING DAYS beginning on the tenth calendar day after the date shown on the Notice to Proceed. It is agreed by the parties to the contract that in case all the work called for under the contract in all parts and requirements, is not finished or completed within the number of days as set forth, damage will be sustained by the CITY, and that it is and will be impracticable and extremely difficult to ascertain the actual damage which CITY will sustain in the event of and by reason of such delay; and it is therefore agreed that CONTRACTOR will pay to CITY the sum of TWO THOUSAND AND NO/100 DOLLARS ($2,000.00) per day for each and every calendar day's delay in finishing the work in excess of the number of days prescribed; and CONTRACTOR agrees to pay said liquidated damages as herein provided, and in case the same are not paid, agrees that CITY, may deduct the amount thereof from any monies due or that may become due CONTRACTOR under the contract.
It is f
urther agreed that in case the work called for under the contract is not finished and completed in all parts and requirements within the number of days as specified, the CITY shall have the right to increase the number of days or not, as may seem best to serve the interest of CITY, and if the CITY decides to increase the said number of days, the CITY shall further have the right to charge to CONTRACTOR, CONTRACTOR's heirs, assigns or sureties, and to deduct from the final payment for the work, all or any part, as EXHIBIT 2
Local Construction Contract – VALENTINE CORPORATION – PROJECT NO. WT22002 (Updated 10/18/23) may be dee
med proper, the liquidated damages as specified or the actual cost of engineering, inspection, superintendence, and other overhead expenses which are directly chargeable to the contract, and which accrue during the period of such extension, whichever is greater, except the cost of final surveys and preparation of final estimate shall not be included in such charges.
A worki
ng day shall not include, nor shall CONTRACTOR be assessed with liquidated damages nor the additional cost of engineering and inspection during any delay beyond the time named for the completion of the work caused by acts of God or of the public enemy, acts of CITY, fire, floods, epidemics, quarantine restrictions, strikes, and freight embargoes and subject to approval by the Director of Public Works , inability to get materials ordered by CONTRACTOR or subcontractor due to such causes provided that CONTRACTOR shall notify the Director of Public Works in writing of the causes of delay within five (5) working days from the beginning of any such delay, and the Director shall ascertain the facts and the extent of the delay, and Director's findings of the facts thereon shall be final and conclusive.
If CON
TRACTOR is delayed by reason of alterations made in these specifications, or by any act of the Director of Public Works or of the CITY, not contemplated by the contract, the time of completion shall be extended proportionately, and CONTRACTOR shall be relieved during the period of such extension of any claim for liquidated damages, engineering or inspection charges or other penalties. CONTRACTOR shall have no claim for any other compensation for any such delay.
7. CONFORMANCE
TO APPLICABLE LAWS. Contractor shall comply with
all applicable Federal, State, and Municipal laws, rules, and ordinances. Contractor shall not discriminate in the employment of persons or in the provision of services under this Contract on the basis of any legally protected classification, including race, color, national origin, ancestry, sex or religion of such person.
a. TITLE VI
Title VI
of the Civil Rights Act of 1964 requires that “no person in the United States shall, on the grounds of race, color, or national origin, be excluded from participation in, be denied the benefits of, or be subjected to discrimination under any program or activity receiving federal financial assistance.” (42 USC Section 2000d)
https://www.dol.gov/agencies/oasam/regulatory/statutes/title-vi-civil-rights- act-of-1964.
The City
of Stockton requires compliance with the requirements of Title VI in all of its programs and activities regardless of funding source. b. DISCRIMI
NATION AND HARASSMENT POLICY
The City
of Stockton has a Discrimination and Harassment Policy ( Exhibit C). The purpose of this policy is to reaffirm the CITY’s commitment to demonstrating respect for all individuals by strictly prohibiting discrimination EXHIBIT 2
Local Construction Contract – VALENTINE CORPORATION – PROJECT NO. WT22002 (Updated 10/18/23) and harassm
ent, including sexual harassment in the workplace, to define the types of behavior and conduct prohibited by this policy, and to set forth a procedure for reporting, investigating, and resolving complaints of discrimination and harassment in the workplace.
c. LABOR ST
ANDARDS PROVISIONS/CALIFORNIA LABOR CODE
The bidder s
hall understand that conditions set forth in Chapter 1, Part 7, Division 2 of the California Labor Code shall be considered part of the contract agreement.
https://leginfo.legislature.ca.gov/faces/codes_displayText.xhtml?lawCode= LAB&division=2.&title=&part=7.&chapter=1.&article=2.
d. PREVAILIN
G WAGE
CONTR
ACTOR and any subcontractor shall pay each employee engaged in the trade or occupation not less than the prevailing hourly wage rate. In accordance with the provisions of Section 1770 of the Labor Code, the Director of Department of Industrial Relations of the State of California has determined the general prevailing wage and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for in Section 1773.1, apprenticeship or other training programs authorized by Section 3093 and similar purposes applicable to the work to be done. CONTRACTOR performing the work under this contract shall obtain a copy of the wage rate determination and shall distribute copies to each subcontractor. As the wage determination for each craft reflects an expiration date, it shall be the prime CONTRACTOR and each subcontractor's responsibility to e nsure that the prevailing wage rates of concern is current and paid to the employee.
i. The CONT
RACTOR performing the work shall be responsible for
obtaining a copy of the State wage rate determination. State wage rates may be obtained at https://www.dir.ca.gov/Public- Works/Prevailing-Wage.html. The CONTRACTOR shall be
responsible for posting said wage rates at a prominent location at the work site and shall maintain same in a good readable condition for the duration of the work.
ii. Should the C
ONTRACTOR choose to work on a Saturday, Sunday or
on a holiday recognized by the Labor Unions, the CONTRACTOR shall reimburse the CITY the actual cost of engineering, inspection, superintendence, and or other overhead expenses which are directly chargeable to the contract. Should such work be undertaken at the request of the CITY, reimbursement will not be required. To conform strictly with the provisions of Division 2, Part 7, Chapter 1, Article 2, of the Labor Code of the State of California. To forfeit as a penalty to CITY the sum of TWENTY -FIVE AND NO/100 DOLLARS ($25.00) for each laborer, worker, or mechanic employed by CONTRACTOR, or by EXHIBIT 2
Local Construction Contract – VALENTINE CORPORATION – PROJECT NO. WT22002 (Updated 10/18/23) any subcontr
actor under CONTRACTOR, in the execution of this
contract, for each calendar day during which any laborer, worker, or mechanic is required or permitted to work more than eight (8) hours and who is not paid the general prevailing rate of per diem wages for holiday and overtime work in violation of the provisions of Sections 1770 to 1781 of the Labor Code of the State of California. That all sums forfeited under the provisions of the foregoing sections shall be deducted from the payments to be ma de under the terms of this contract.
iii. The CON
TRACTOR to whom the contract is awarded shall ensure that the prime and each subcontractor will in accordance with Section 1776 of the Labor Code, maintain certified payroll records. A copy of said records shall be provided with each invoice to the Public Works Department, Attention Contract Complianc e Officer. It shall be the CONTRACTOR’S responsibility to obtain copies of the current prevailing wage rate determination for all subcontractors. Additionally, certified payroll records must be uploaded to the DIR website as required by labor code.
iv. The CONT
RACTOR shall comply with the provisions established in
Section 1777.5 of the Labor Code concerning the 1) certified approval by local joint apprenticeship committees for the employment and training of apprentices, and 2) contribution of funds to administer and conduct apprenticeship programs, if applicable to the job. e. LOCAL E
MPLOYMENT ORDINANCE
Pursuant
to Stockton Municipal Code Section 3.68.095 the CONTRACTOR and all subcontractors shall make a good faith effort to employ at least 50 percent of the workforce on this project from local residents, as measured by total labor work hours. Failure of any CONTRACTOR or subcontractor to comply with these requirements shall be deemed a material breach of the contract or subcontract. CONTRACTORS and subcontractors shall maintain records necessary for monitoring their compliance with section
3.68.095.
f. SANCTIO
NS
Deliver
ables must conform with all applicable federal, state, and local laws. Such conformity includes compliance with federal sanctions, and Contractor certifies that it has not and will not engage in prohibited transactions with sanctioned persons or entities.
CITY agr
ees:
8. COMPENS
ATION. To pay CONTRACTOR for the work herein
contemplated in the following manner: Progress payments will be made on or about the EXHIBIT 2
Local Construction Contract – VALENTINE CORPORATION – PROJECT NO. WT22002 (Updated 10/18/23) first
day of each calendar month, in such sum as shall make the aggregate of payment up to such day equal to ninety-five percent (95%) of the proportional contract price, upon the basis of the progress certificate of the Director of Public Works as to the amount of work done and the proportional amount of the contract price represented therefor e; and all of the remaining part of the contract price not as aforesaid paid, shall be paid at the expiration of thirty-five (35) days from the completion of said work of construction and the certification by the Director of Public Works of such completion.
9. SECURIT
IES. Pursuant to Section 22300 of the Public Contract Code, CONTRACTOR will be permitted, at its request and sole expense, to substitute securities for any monies withheld by the CITY to ensure performance under the contract. Said securities will be deposited either with the CITY or with a State or federally chartered bank as escrow agent. Securities eligible for this substitution are those listed in Section 16430 of the California Government Code or bank or savings and loan certificates of depos it.
CONTRACTOR shall be the beneficial owner of any securities substituted for monies withheld and shall receive any interest thereon.
10. CHANGE ORDE
RS. CITY reserves the right to make such alterations,
deviations, additions to or omissions from the plans and specifications, including the right to increase or decrease the quantity of any item or portion of the work, as may be deemed by the Engineer to be necessary or advisable and to require such extra work as may be determined by the Engineer to be required for the proper completion or construction of the whole work contemplated.
Any such
changes will be set forth in a contract change order which will specify, in addition to the work done in connection with the change made, adjustment of contract time, if any, and the basis of compensation for such work. A contract change order wi ll not become effective until approved by the City Manager and/or the City Council.
Process
ing of change orders shall be in accordance with Section 4- 1.05A of the City of Stockton Standard Specifications and Plans as adopted by Council on September 27, 2016, by Resolution No. 2016-09-27-1213, effective September 27, 2016, or as otherwise amended by Council. When the compensation for an item of work is subject to adjustment under the provisions of Standard Specifications and Plans, Section 4- 1.05A, CONTRACTOR shall, upon request, promptly furnish the Engineer with adequate detailed cost data for such item of work.
11. AUDITS. CI
TY reserves the right to periodically audit all charges made by CONTRACTOR to CITY for services under the contract. Upon request, CONTRACTOR agrees to furnish CITY, or a designated representative, with necessary information and assistance.
CONTR
ACTOR agrees that CITY or its delegate will have the right to review, obtain and copy all records pertaining to performance of the contract. CONTRACTOR agrees to provide CITY or its delegate with any relevant information requested and shall permit CITY or its delegate access to its premises, upon reasonable notice, during normal business hours for the purpose of interviewing employees and inspecting and copying such books, records, accounts, and other material that may be relevant to a matter under EXHIBIT 2
Local Construction Contract – VALENTINE CORPORATION – PROJECT NO. WT22002 (Updated 10/18/23)
investigation for the purpose of determining compliance with this requirement.
CONTRACTOR further agrees to maintain such records for a period of three (3) years after final payment under the contract.
12. WAIVER. It is expressly understood and agreed by and between the parties hereto that a waiver of any of the conditions of this contract shall not be considered a w�iver of any of the other conditions thereof.
It is further understood and agreed by and between the parties hereto that time is of the essence of this contract in all respects.
IN WITNESS WHEREOF, the parties hereto have hereunto affixed their hands and seals the day and year first above written.
ATTEST: CITY:
KATHERINE ROLAND, CMC, CPMC
CITY CLERK
By: ____________ _
APPROVED AS TO FORM & CONTENT:
LORI M. ASUNCION
OFFICE OF THE CITY ATTORNEY
By:-------------
DEPUTY CITY ATTORNEY
By: ____________ _
STEVE COLANGELO
INTERIM CITY MANAGER
By: Bd"t..LT O ��
VALENTINE CORPORATION
Robert 0. Valentine - President
94-1580884
Tax Identification No.
Local Construction Contract-VALENTINE CORPORATION -P ROJECT NO. WT22002 (Updated 10/18/23) EXHIBIT 2
EL DORADO STREET BRIDGE OVER BIANCHI
PROJECT NO. WT22002
BI D DING SCHEDULE
Each bidder shall bid each item, including all alternate bid(s). Failure to bid an item shall be just cause for considering the bid as non-responsive. Line item costs should include all Contractor's overhead and profit and indirect costs. Bids not presented on City forms shall be cause for considering the bid as non-responsive.
Item Description Unit Quantity Unit price Total Price
1 2
3 4
5 6
7 8
Bid Forms
MOBILIZATION/GENERAL CONDITIONS
TRAFFIC CONTROL & SIGNAGE
BRIDGE DECK TEMPORARY SHORING
DAMAGED COLUMN PARTIAL DEMOLITION
INSTALL MIDWEST GUARDRAIL SYSTEM W/
STEEL POSTS & END ANCHOR ASSEMBLY
INSTALL GUARDRAIL IN-LINE TERMINAL END
TREATMENT(CAL TRANS APPROVED)
COLUMN REPAIR
EROSION CONTROL
LS
LS
LS
LS
LF
EA
LS
LS
1 1
1 1
160
1 1
1 -�� 1;?b1
--
�J/;?i/J
.t.
�
$ ....lk2- ��
c?� 1}1)0 $"d�aPt>-
BIDDER'S NAME Valentine Corporation
Last Revised 03/05/2024
EXHIBIT 2
EXHIBIT A
BIDDER CERTIFICATION
The undersigned agrees that if this bid is accepted, he/she will contract with the City of Stockton in the form of contract attached hereto to perform all of the work in accordance with the contract and the drawings, specifications, and other documents incorporated therein; that he/she will take in full payment therefor, and for all other obligations assumed under the contract, the prices set forth in the following bid schedule except as otherwise provided in the specifications; and that he/she will execute such contract and furnish the required contract bonds in the manner and within the time provided in the bidding requirements and conditions. The undersigned further agrees that he/she has carefully examined the site of the work and the bid documents and any addenda thereto, and is fully informed of the nature and location of the work, the quantities of the work, and the conditions to be encountered in performing the work; that the only parties interested in this bid as principals are those named herein and that this bid is made without collusion with any other party; and that this bid is submitted in all respects in accordance with the bidding requirements and conditions and all other requirements of the bid documents.
A BID GUARANTY ACCOMPANIES THIS BID IN THE FORM OF: (Check one of the following) □ □ □
[x]
Cash, or
Cashier's check, or
Certified check payable to City of Stockton, or
Bidder's bond in favor of the City.
For any amount not less than ten percent (10%) of the aggregate of the bid.
ALSO ACCOMPANYING THIS BID ARE THE FOLLOWING ATTACHMENTS, PROPERLY EXECUTED AND SIGNED:
1. 2.
3. List of Subcontractors
Non-Collusion Declaration
DIR Self-Certification
4. Title VI Self-Certification
5. Local Employment Ordinance Acknowledgement
6. Local Business Preference Acknowledgement
THE CITY RESERVES THE RIGHT TO REJECT ANY AND ALL BIDS
Valentine Corporation 415-453-3732
Name of Firm Phone
111 Pelican Way San Rafael, CA 94901
Address City
229225 A, B & HAZ
Contractor Lie. No. & Classification
State
94-1580884
Tax I.D. No.
Zip
01/31/26
Expiration Date
NOTE - State law requires bidders on public agency contracts to include on their bid: (1) their State contractors license number, (2) the license expiration date, and (3) a statement that the representations made therein are made under penalty of perjury. The law further states that "Any bid not containing this information, or bid containing information which is substantially proven false shall be considered non-responsive and shall be rejected by the public agency."
THE REPRESENTATIONS MADE HEREIN ARE MADE UNDER PENALTY OF PERJURY e�o.14�
Signature Robert O. Valentine
Bid Forms
BIDDER SIGN
¢::: HERE President ----------
Title
Last Revised 03/05/2024
EXHIBIT 2
EXHIBIT A
10/10/24, 9:18AM
bep.airrm,r«t ii
t:11du1tri1l �tMinis
Valentine Corporation
eCPR Public Search
Public Works Support
Contractors
Projects
Services
Your information ..,.
.1::1,QIT.l.� ) .�!J.$.t.9..m.!;lr,,,/.;\f,f..Q!J.D..t!.9.9.IS.YP. ) Valentine Corporation Valentine Corporation
Customer Account Lookup
Name
l Valentine Corporation
Customer Account
Type
RJ
RJ Reinnia Jennings
Logout
1 /4
EXHIBIT 2
EXHIBIT A
10/10/24, 9:18AM
Website
(empty)
Email
[email protected]
Address 1
111 Pelican Way
Address_2
City
San Rafael
State
CA
Zip
Contractor Status
; DIR Approved
CSLB
Legal Name
VALENTINE CORPORATION
Business Structure
: -- None --
Valentine Corporation
2/4
EXHIBIT 2
EXHIBIT A
10/10/24, 9: 18 AM Valentine Corporation
Business Phone
4154533732
'•-" . .,. _ _,,.,�•�"" ,,..,. ~ '" =••••""'"� •~•• =•"=•••-•~ ,-.e•==•�,�-�.,•�•-•-•-�=" • � • • • ""'�' ••� ""• '""' ••• ,_.-�••••�= ,.._, �•�,-,. ., . ._,c.,, •••� ,,_ � • •· • � �,. •• , ••• ' Registration Number
, " - ,.,.,,,_ �""''""" ••=••• ,,w,-• -v-.m ••"""""'•"�• ••�•• ••• " .,.,..,.,,_,.,,,, '"'" ,- , ••••••• •~ •• • .,,_u•••�•""'�••••M"-•••~"''�"" ~-----�"., .. ,,.,,_, ,.,,_,_,,,,_,,, .. ,.,"""" President
Robert 0. Valentine Jr.
PWCR
Registration Start Date
2024-07-01
Registration End Date
2027-06-30
Doing Business As (OBA)
Crafts
Carpenter Cranes, Pile Driver and Hoisting Equipment (Operating Engineer) Operating Engineer Laborer and Related Classifications Carpenter and Related Trades Pile Driver (Carpenter) Cement Mason
PILE DRIVER (OPERATING ENGINEER-HEAVY AND HIGHWAY WORK) Dredger (Operating Engineer) Operating Engineer (Heavy and Highway Work) : LABORER Legacy Registration Date
Legacy Registration Expiration
3/4
EXHIBIT 2
EXHIBIT A
LIST OF SUBCONTRACTORS
GENERAL CONTRACTOR: Valentine Corporation
PROJECT: El Dorado Street Bridge Over Bianchi
PLEASE LIST BELOW ALL SUBCONTRACTORS CONTRIBUTING TO THIS WORK Each bidder shall give the name, business address, license number, description of the work, and the dollar amount to be PAID the subcontractor, for each subcontractor that will be used on the project, if the Bidder is awarded the contract. Only subcontractors with work in excess of one-half of one percent (0.5%) or $10,000 (whichever is greater) of the Bidder's total bid need to be listed. All work in excess of one-half of one percent (0.5%) or $10,000 (whichever is greater) of the Bidder's total bid, for which a subcontractor is not listed on this form, shall be performed by the Bidder's own organization.
Additional numbered pages listing proposed subcontractors may be attached to this page. Each page shall be headed "Proposed Subcontractors" and shall be signed by the Bidder.
PRINT LEGIBLY OR TYPE
BUSINESS LICENSE DEPT. OF
NAME/ADDRESS NUMBER & INDUSTRIAL
LICENSE RELATIONS
CLASSIFICATION REGISTRATION
NUMBER
M1d�-fe IJ,irr,e;r
'-��/« • -• .. ft.tJ- 6::l1t,2/ /t'�M.53�
r:::;, , / BIDDER SIGN
,tCt>�E.,t(.:T 0, 1,/,q'-A-.... -- <= HERE �------�------- (SIGNATURE OF BIDDER)
Robert 0. Valentine - President
Bid Forms
TYPE OF WORK
M tdt,v��
�1,..o--l,1r.-4 I
AMOUNT
f.1:u>.1� -
Last Revised 03/05/2024
EXHIBIT 2
EXHIBIT A
Exhibit B:
Insurance Requirements
(WT22002)
Contractor shall procure and maintain for the duration of the contract, and for five (5) years thereafter, insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his agents, representatives, employees, or subcontractors.
MINIMUM SCOPE AND LIMIT OF INSURANCE
Coverage shall be at least as broad as:
1. Comm
ercial General Liability (CGL): Insurance Services Office (ISO) Form CG 00 01 covering CGL on an “occurrence” basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $3,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit.
2. Auto
mobile Liability: Insurance Services Office Form CA 0001 covering Code 1 (any auto), with limits no less than $2,000,000 per accident for bodily injury and property damage.
3. Workers
’ Compensation insurance as required by the State of California, with Statutory Limits, and Employers’ Liability insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.
4. Build
er’s Risk (Course of Construction) insurance utilizing an “All Risk” (Special Perils) coverage form, with limits equal to the completed value of the project and no coinsurance penalty provisions.
If the
contractor maintains broader coverage and/or higher limits than the minimums shown above, the City of Stockton requires and shall be entitled to the broader coverage and/or the higher limits maintained by the contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City of Stockton.
Self -Insured Retentions
Self
-insured retentions must be declared to and approved by the City of Stockton. The City of Stockton may require the Contractor to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim EXHIBIT 2
EXHIBIT B
administration, and defense expenses within the retention. The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the named insured or City of Stockton. The CGL and any policies, including Excess liability policies, may not be subject to a self-insured retention (SIR) or deductible that exceeds $25,000 unless approved in writing by City of Stockton. Any and all deductibles and SIRs shall be the sole responsibility of Contractor or subcontractor who procured such insurance and shall not apply to the Indemnified Additional Insured Parties. City of Stockton may deduct from any amounts otherwise due Contractor to fund the SIR/deductible. Policies shall NOT contain any self-insured retention (SIR) provision that limits the satisfaction of the SIR to the Named Insured.
The policy must also provide that Defense costs, including the Allocated Loss Adjustment Expenses, will satisfy the SIR or deductible. City of Stockton reserves the right to obtain a copy of any policies and endorsements for verification.
Other I
nsurance Provisions
The i
nsurance policies are to contain, or be endorsed to contain, the following provisions:
1. The Cit
y of Stock ton, its officers, officials, employees, and volunteers are to be covered as additional insureds on the CGL policy with respect to liability arising out of work or operations performed by or on behalf of the Contractor including materials, parts, or equipment furnished in connection with such work or operations and automobiles owned, leased, hired, or borrowed by or on behalf of the Contractor.
General liability coverage can be provided in the form of an endorsement to the Contractor’s insurance (at least as broad as ISO Form CG 20 10, CG 11 85 or both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 forms if later revisions used).
Additional insured Name of Organization shall read “City of Stockton, its officers, officials, employees, and volunteers.” Policy shall cover City of Stockton, its officers, officials, employees, and volunteers for all locations work is done under this contract.
2. For
any cl
aims related to this project, the Contractor’s insurance coverage shall be primary and non-contributory insurance coverage at least as broad as ISO CG 20 01 04 13 as respects the City of Stockton, its officers, officials, employees, and volunteers. Any insurance or self-insurance maintained by the City of Stockton, its officers, officials, employees, or volunteers shall be excess of the Contractor’s insurance and shall not contribute with it. This requirement shall also apply to any Excess or Umbrella liability policies. The City of Stockton does not accept endorsements limiting the Contractor’s insurance coverage to the sole negligence of the Named Insured.
3. Each
insurance policy required by this clause shall provide that coverage shall not be canceled, except with notice to the City of Stockton.
Builder’s Risk (Course of Construction) Insurance
EXHIBIT 2
EXHIBIT B
Contractor may submit evidence of Builder’s Risk insurance in the form of Course of Construction coverage. Such coverage shall name the City of Stockton as a loss payee as their interest may appear.
If the
project does not involve new or major reconstruction, at the option of the City of Stockton, an Installation Floater may be acceptable. For such projects, a Property Installation Floater shall be obtained that provides for the improvement, remodel, modification, alteration, conversion or adjustment to existing buildings, structures, processes, machinery and equipment. The Property Installation Floater shall provide property damage coverage for any building, structure, machinery or equipment damaged, impaired, broken, or destroyed during the performance of the Work, including during transit, installation, and testing at the City of Stockton’s site.
Claims
Made Policies (Professional & Pollution only)
If any coverage required is written on a claims-made coverage form:
1. The r
etroactive date must be shown, and this date must be before the execution date of the contract or the beginning of contract work.
2. Insura
nce must be maintained and evidence of insurance must be provided for at least five (5) years after completion of contract work.
3. If co
verage is cancelled or non-renewed, and not replaced with another claims- made policy form with a retroactive date prior to the contract effective, or start of work date, the Contractor must purchase extended reporting period coverage for a minimum of five (5) years after completion of contract work.
4. A co
py of the claims reporting requirements must be submitted to the City of Stockton for review.
5. If the
services involve lead-based paint or asbestos identification/remediation, the Contractors Pollution Liability policy shall not contain lead-based paint or asbestos exclusions. If the services involve mold identification/remediation, the Contractors Pollution Liability policy shall not contain a mold exclusion, and the definition of Pollution shall include microbial matter, including mold.
Umbrella or Excess Policies
The Contractor may use Umbrella or Excess Policies to provide the liability limits as required in this agreement. This form of insurance will be acceptable provided that all of the Primary and Umbrella or Excess Policies shall provide all of the insurance coverages herein required, including, but not limited to, primary and non-contributory, additional insured, Self-Insured Retentions (SIRs), indemnity, and defense requirements. The Umbrella or Excess policies shall be provided on a true “following form” or broader coverage basis, with coverage at least as broad as provided on the EXHIBIT 2
EXHIBIT B
underlying Commercial General Liability insurance. No insurance policies maintained by the Additional Insureds, whether primary or excess, and which also apply to a loss covered hereunder, shall be called upon to contribute to a loss until the Contractor’s primary and excess liability policies are exhausted.
Acceptability of Insurers
Insurance is to be placed with insurers authorized to conduct business in the state with a current A.M. Best rating of no less than A: VII, unless otherwise acceptable to the City of Stockton.
Waiver of Subrogation
Contractor hereby agrees to waive rights of subrogation which any insurer of Contractor may acquire from Contractor by virtue of the payment of any loss.
Contractor agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation. The Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of the City of Stockton for all work performed by the Contractor, its employees, agents and subcontractors.
Verification of Coverage
Contr
actor shall furnish the City of Stockton with original certificates and amendatory endorsements or copies of the applicable policy language effecting coverage required by this clause and a copy of the Declarations and Endorsements Pages of the CGL and any Excess policies listing all policy endorsements. All certificates and endorsements and copies of the Declarations & Endorsements pages are to be received and approved by the City of Stockton before work commences. However, failure to obtain the required documents prior to the work beginning shall not waive the Contractor’s obligation to provide them. The City of Stockton reserves the right to require complete, certified copies of all required insurance policies, including endorsements required by these specifications, at any time. City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances.
Subcontractors
Contractor shall require and verify that all subcontractors maintain insurance meeting all requirements stated herein, and Contractor shall ensure that City of Stockton is an additional insured on insurance required from subcontractors. For CGL coverage, subcontractors shall provide coverage with a form at least as broad as CG 20 38 04 13.
Duration of Coverage
CGL & Excess liability policies for any construction related work, including, but not limited to, maintenance, service, or repair work, shall continue coverage for a minimum of 5 years for Completed Operations liability coverage. Such Insurance must EXHIBIT 2
EXHIBIT B
be maintained and evidence of insurance must be provided for at least five (5) years after completion of the contract of work.
Surety Bonds
Contractor shall provide the following Surety Bonds:
1. Bid B
ond
2. Performance Bond
3. Payment Bond
4. Maintenance Bond
The P
ayment Bond and the Performance Bond shall be in a sum equal to the contract price. If the Performance Bond provides for a one-year warranty a separate Maintenance Bond is not necessary. If the warranty period specified in the contract is for longer than one year a Maintenance Bond equal to 10% of the contract price is required. Bonds shall be duly executed by a responsible corporate surety, authorized to issue such bonds in the State of California and secured through an authorized agent with an office in California.
Special Risks or Circumstances
City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other circumstances.
Certi
ficate Holder Address
The a
ddress for mailing certificates, endorsements and notices shall be:
City
of Stockton
Its Officers, Officials, Employees and Volunteers
400 E Main Street, 3rd Floor – HR
Stockton, CA 95202
EXHIBIT 2
EXHIBIT B
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
EXHIBIT 2
EXHIBIT C
BOND FOR FAITHFUL PERFORMANCE
KNOW ALL MEN BY THESE PRESENTS:
Bond No. 9408099
Premium: $1,172.00
That we, Valentine Corporation ' a STATE OF CALIFORNIA
CORPORATION, as Principal and Fidelity and Deposit Company of Maryland _______ , a corporation, organized and existing under the laws of the State of Illinois and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, as obligee, in the just and full sum of ONE HUNDRED TWENTY SEVEN THOUSAND THREE HUNDRED SIXTY-NINE AND 00/100 DOLLARS ($127,369}, in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to the said CITY, the said Principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.
The condition of the foregoing obligation is such that the above bounded Principal has simultaneously entered into a contract with the CITY, to do and perform the following work, to wit:
EL DORADO STREET BRIDGE OVER BIANCHI
PROJECT NO. WT22002
NOW, THEREFORE, if the above bounded Principal, CONTRACTOR, Company or
Corporation or its subcontractor, shall well and truly perform the work contracted to be done under said contract, then this obligation to be null and void; otherwise to remain in full force and effect.
No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract, or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY, and no forbearance on the part of
EXHIBIT 2
the said CITY shall operate to relieve any Surety or Sureties from liability on this bond, and consent by said Surety is hereby given, and the said Surety hereby waives the provisions of Sections 2819 and 2845 of the Civil Code of the State of California.
SIGNED AND SEALED on May 8, 2025----------------
APPROVED AS TO SURETY:
APPROVED AS TO FORM & CONTENT:
LORI M. ASUNCION
OFFICE OF THE CITY ATTORNEY
By:----------
DEPUTY CITY ATTORNEY
Valentine Corporation
By:&e�t:J.�
PRINCIPAL
Robert 0. Valentine, President
Fidelity and Deposit Company of Maryland
SURETY
onathan Russell, ATTORNEY-IN-FACT
EXHIBIT 2
EXTRACT FROM BY-LAWS OF THE COMPANIES
"Article V, Section 8, Attorneys-in-Fact. The Chief Executive Officer, the President, or any Executive Vice President or VicePresident may, by written instrument under the attested corporate seal, appoint attorneys-in-fact with authority to execute bonds, polices, recognizances, stipulations, undertakings, or other like instruments on behalf of the Company, and may authorize any officer orany such attorney-in-fact to affix the corporate seal thereto; and may with or without cause modify of revoke any such appointment or auhority at any time."
CERTIFICATE
I, the undersigned, Vice President of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the foregoing Power of Attorney is still in full force and effect on the date of this certificate; and I do further certify that Aticle V, Section 8, of the By-Laws of the Companies is still in force.
This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Boa:d of Directors of the ZURICH AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 15th day of December 1998.
RESOLVED: "That the signature of the President or a Vice President and the attesting signature of a Secretary or an AssistantSecretary and the Seal of the Company may be affixed by facsimile on any Power of Attorney ... Any such Power or any certificate thereof bmring such facsimile signature and seal shall be valid and binding on the Company." This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Boa:d of Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a meeting duly called and held on the 5th day of May, 1994, and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 10th day of May, 1990.
RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signatue of any Vice-President, Secretary, or Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearhg upon a certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same forceand effect as though manually affixed.
IN mIIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seals of the said Companies, this_�...,.___ day of M�y 2-{)2S .
Mary Jean Pethick
Vice President
TO REPORT A CLAIM WITH REGARD TO A SURETY BOND, PLEASE SUBMIT A COMPLETE DESCRIPTION
OF THE CLAIM INCLUDING THE PRINCIPAL ON THE BOND, THE BOND NUMBER, AND YOUR CONT ACT INFORMATION TO:
Zurich Surety Claims
1299 Zurich Way
Schaumburg, IL 60196-1056
[email protected]
800-626-4577
Authenticity of this bond can be confirmed at bondvalidator.zurichna.com or 410-559-8790 EXHIBIT 2
CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.
STATE OF CALIFORNIA
County of Contra Costa }
On _5_/,__-S�/_z_S--___ before me, Carol B. Henry , Notary Public, Date In sert Name of Notary exactly as it appears on the official seal personally appeared Jonathan Russell ---------------,-,Na_m_e.,...(s,-) o-:-r=si-gn-er....,.(s.,...) -------------- � : •:: e e �:L�. :N� e e
�
- Notary Public - California
! � Contra Costa County !
y I? Commission # 2481886 -
My Comm. Expires Feb 15, 2028
Place Notary Seal Above
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
I certify under PENALTY OF PERJURY under the laws of
the State of California that the foregoing paragraph is true and correct.
Witness my ha tn officia
Signature '/)
OPTIONAL
Though the information below is not required by law, it may prove valuable and could prevent fraudulent removal and reattachment of the i ersons relying on the document
to another document.
Description of Attached Document
Title or Type of Document: ------------------------------- Document Date: __________________ _ Number of Pages: ________ _ Signer(s) Other Than Named Above: __________________________ _ Capacity(ies) Claimed by Signer(s)
Signer's Name: Jonathan Russell
0 Individual
O Corporate Officer -Title(s): ________ _
0 Partner D Limited O General
rl! Attorney in Fact
O Trustee
D Guardian or Conservator
0 Other: ______ _
Signer is Representing:
RIGHT THUMBPRINT
OF SIGNER
Top of thumb here
Signer's Name: _____________ _
D Individual
O Corporate Officer -Title(s): ________ _
D Partner D Limited D General
0 Attorney in Fact
O Trustee
O Guardian or Conservator
D Other: ______ _
Signer is Representing:
RIGHT THUMBPRINT
OF SIGNER
Top of thumb here
EXHIBIT 2
BOND FOR LABOR AND MATERIAL
KNOW ALL MEN BY THESE PRESENTS:
Bond No.: 9408099
Premium: Included in
Performance Bond
That we, VALENTINE CORPORATION, a STATE OF CALIFORNIA
CORPORATION, as Principal and Fidelity and Deposit Company of Maryland , corporation, organized and existing under the laws of the State of Illinois and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, and unto any and all material suppliers, persons, companies, or corporations furnishing materials, provisions, provender or other supplies used in, upon, for or about the performance of the work contemplated to be executed or performed under the contract hereinafter mentioned, and all persons, companies, or corporations renting or hiring teams, or implements of machinery, for or contributing to said work and all persons who perform work or labor upon the same, and all persons who supply both work and materials, and whose claims have not been paid by the contractor, company or corporation in the just and full sum of ONE HUNDRED TWENTY-SEVEN THOUSAND THREE HUNDRED SIXTY-NINE AND 00/100 DOLLARS ($127,369), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to said CITY and to said persons jointly and severally, the said principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.
The condition of the foregoing obligations is such that the above bounden Principal has simultaneously entered into a contract of even date herewith, with the CITY, to do and perform the following work, to-wit:
EL DORADO STREET BRIDGE OVER BIANCHI
PROJECT NO. WT22002
NOW, THEREFORE, if the above bounden Principal, CONTRACTOR, Company or Corporation or its subcontractor, fail to pay for all materials, provisions, provender, or other supplies, or teams, used in, upon, for or about the performance of the work
EXHIBIT 2
contracted to be done, or for any work or labor done thereon of any kind, the Surety on this bond will pay the same, in an amount not exceeding the sum specified in this bond, provided that any and all claims hereunder shall be filed and proceedings had in connection therewith as required by the provisions of Division 3, Part 4, Title 15, Chapter 5, Article 1 of the Civil Code of California, provided that in case suit is brought upon this bond, a reasonable attorney's fee shall be awarded by the Court to the prevailing party in said suit; said attorney's fee to be fixed as costs in said suit, and to be included in the judgment therein rendered.
No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY and no forbearance on the part of the said CITY shall operate to relieve any surety or sureties from liability on this bond, and consent to make such alterations without further notice to or consent by any such surety is hereby given, and the said sureties hereby waive the provisions of Sections 2819 and 2845 of the Civil Code of the State of California.
SIGNED AND SEALED on __ M_a ....;_y_8_, _20_ 2_5 _________ ----= Valentine Corporation
APPROVED AS TO SURETY:
APPROVED AS TO FORM & CONTENT:
LORI M. ASUNCION
OFFICE OF THE CITY ATTORNEY
By:-----------
DEPUTY CITY ATTORNEY
By: &eAr CJ.¼�
PRINCIPAL . d Robert O. Valentine, Presi ent
Fidelity and Deposit Company of Maryland
SURETY
onathan Russell, ATTORNEY-IN-FACT
EXHIBIT 2
EXTRACT FROM BY-LAWS OF THE COMPANIES
"Article V, Section 8, Attorneys-in-Fact. The Chief Executive Officer, the President, or any Executive Vice President or VicePresident may, by written instrument under the attested corporate seal, appoint attorneys-in-fact with authority to execute bonds, polices, recognizances, stipulations, undertakings, or other like instruments on behalf of the Company, and may authorize any officer orany such attorney-in-fact to affix the corporate seal thereto; and may with or without cause modify ofrevoke any such appointment or atthority at any time."
CERTIFICATE
I, the undersigned, Vice President of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERJCAN CASUALTY AND SURETY COMPANY, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the foregoing Power of Attorney is still in full force and effect on the date of this certificate; and I do further certify that Aticle V, Section 8, of the By-Laws of the Companies is still in force.
This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Boa:d of Directors of the ZURICH AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 15th day of December 1998.
RESOLVED: "That the signature of the President or a Vice President and the attesting signature of a Secretary or an AssistantSecretary and the Seal of the Company may be affixed by facsimile on any Power of Attorney ... Any such Power or any certificate thereofbwring such facsimile signature and seal shall be valid and binding on the Company." This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Boa:d of Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a meeting duly called and held on the 5th day of May, 1994, and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMP ANY OF MARYLAND at a meeting duly called and held on the 10th day of May, 1990.
RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signatue of any Vice-President, Secretary, or Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearilg upon a certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same forceand effect as though manually affixed.
INJ,�TIMONY WHE�OF, I have hereunto sub�bed my name and affixed the corporate seals of the said Companies, this_...,/).�- day of Mg,Y 1,-oZ,,':2_ .
Mary Jean Pethick
Vice President
TO REPORT A CLAIM WITH REGARD TO A SURETY BOND, PLEASE SUBMIT A COMPLETE DESCRIPTION
OF THE CLAIM INCLUDING THE PRINCIPAL ON THE BOND, THE BOND NUMBER, AND YOUR CONTACT INFORMATION TO:
Zurich Surety Claims
1299 Zurich Way
Schaumburg, IL 60196-1056
[email protected]
800-626-4577
Authenticity of this bond can be confirmed at bondvalidator.zurichna.com or 410-559-8790 EXHIBIT 2
CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.
STATE OF CALIFORNIA
County of Contra Costa }
On __ 5' ____ /_-g_/_2-_S--___ before me, Carol B. Henry , Notary Public, Date Insert Name of Notary exactly as it appears on the official seal personally appeared Jonathan Russell--------------�Na-
me
,--(s)�o�f s=
ig-n-er�(s�) --------------
········�
CAROL B. HENRY
Notary Public • California
Contra Costa County !
Commission # 2481886 -
y Comm. Expires Feb 15, 2028
Place Notary Seal Above
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
I certify under PENALTY OF PERJURY under the laws of
the State of California that the foregoin� paragraph is true and correct. ,,,.,
Witness my
Signature -=-+��'l"-:-,--=-J":r-�---------
OPTIONAL
Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document.
Description of Attached Document
Title or Type of Document: ------------------------------- Document Date: ------------------- Number of Pages: ________ _ Signer(s) Other Than Named Above: _________ _____ ____________ _ Capacity(ies) Claimed by Signer(s)
Signer's Name: Jonathan Russell
0 Individual
O Corporate Officer -Title(s): ________ _
0 Partner O Limited O General
� Attorney in Fact
O Trustee
O Guardian or Conservator
0 Other: _______ _
Signer is Representing:
RIGHT THUMBPRINT
OF SIGNER
Top of thumb here
Signer's Name: _____________ _
D Individual
O Corporate Officer -Title(s): ________ _
D Partner D Limited D General
D Attorney in Fact
O Trustee
O Guardian or Conservator
0 Other: ______ _
Signer is Representing:
RIGHT THUMBPRINT
OF SIGNER
Top of thumb here
EXHIBIT 2