your backbone for IT
Basement Quote #1 Revision 2
City of Vernon
Attn: Ernesto Smith
CMAS Agreement Number: 3-23-01-1017
Martin Phan
Technology Consultant
[email protected]
408.367.9452
City of Vernon-Basement Quote #1_Rev2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 2
SCOPE OF WORK
Date: November 24, 2025
Quote: 25-703_Rev2
Provide labor and material to install access control hardware within customers Vernon facility.
Access Control Door:
Provide materials and labor to install new access control hardware to customer specified locations.
• Install (1ea) Verkada card reader to (14) locations.
• Install (2) 18/4 Awg cable to (1) door location
• Install (1) Push Button (red)
o WCC to use existing cable at push button location
• Install (6) DPI door contacts.
o WCC to use existing access control cabling at door locations. o WCC to terminate existing access control cabling onto new door controller. o WCC will provide back plates at all card reader locations • This quote assumes that WCC will utilize customer installed locks, REX, door contact, and transfer hinges.
Access Control Panel & Battery Installation:
• Install (1) Verkada AC62 to customer specified locations. • Install (1) Verkada 18AH Backup Battery
City of Vernon-Basement Quote #1_Rev2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 3 Our Background and Company Story
WCC Technologies Group
WCC Technologies Group is a full-service technology integrator specializing in network infrastructure, physical security, collaboration systems, and IT solutions. Founded in 2003, we’ve built our reputation on delivering clean, reliable technology tailored to each client’s environment, budget, and timeline.
Headquartered in Southern California, we serve school districts, public agencies, and enterprise organizations that require dependable execution and responsive support. Our team holds active C7 (Low Voltage), C10 (Electrical), and C28 (Lock & Security Equipment) contractor licenses, enabling us to deliver fully integrated solutions with inhouse expertise across critical systems.
From structured cabling and wireless networks to surveillance, access control, and firerated backbone infrastructure, WCC Technologies Group manages every project with precision, safety, and long-term value in mind.
We recently changed our name from West Coast Cable to WCC Technologies Group to reflect our growth beyond cabling into complete end-to-end technology services.
While our name has evolved, our commitment to reliability, accountability, and client partnership remains unchanged.
What Sets Us Apart
• Turnkey technology solutions from cabling to IT systems • 20+ years of experience across education, enterprise, and government • Licensed C7, C10, and C28 contractor for complete in-house execution • Clean, professional installations built for long-term performance • Responsive, communicative project management
• Ongoing investment in people, training, and innovation At WCC Technologies Group, we combine technical expertise with a strong service culture. We’re building the go-to partner for organizations that value quality, consistency, and forward-thinking technology integration.
City of Vernon-Basement Quote #1_Rev2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 4 Bill of materials - Pricing
Item Description Part Number Qty
Unit List
Price Extended List % Disc Total Price
HARDWARE
AC62 16 Door Controller AC62-HW 1 $5,299.00 $5,299.00 22% $4,133.22 18AH Backup Battery ACC-BAT-18AH 1 $699.00 $699.00 22% $545.22 AD34 Multi-format Card
Reader AD34-HW 14 $349.00 $4,886.00 22% $3,811.08
BR12 Wired Surface
Mount Door Contact, 5
Pack BR12-HW 2 $99.00 $198.00 22% $154.44
SOFTWARE
3-Year Door License,
Capacity Increase LIC-AC-3Y-CAP 14 $599.00 $8,386.00 22% $6,541.08 Hardware $8,643.96
Software $6,541.08
Material $993.56
Labor $10,852.80
Sales Tax $1,011.94
Shipping $0.00
Total Project Price $28,043.34
City of Vernon-Basement Quote #1_Rev2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 5
MASTER SERVICES AGREEMENT (MSA)
WCC Technologies Group
1. Scope of Work
WCC Technologies Group agrees to perform services as detailed in one or more projectspecific Statements of Work (SOWs). Each SOW will include a description of services, deliverables, pricing, timeline, and payment terms. Either party may serve as service provider or recipient under individual SOWs. All provisions of this Agreement apply equally regardless of which party issues the SOW.
Customer is responsible for all costs associated with permits, easements, and/or rights-ofway.
2. Term
This Agreement shall begin on the date it is signed by all parties and shall remain in effect for one (1) year from that date.
3. Payment Terms
Client agrees to pay WCC Technologies Group according to the following project milestones, unless otherwise specified in the applicable Statement of Work (SOW):
• 50% due upon signing contract
• 40% due on delivery of equipment
• 10% due at completion of project
Invoices are due Net 30 from the date of invoice.
A 2% discount will be applied to invoices paid within 15 calendar days of the invoice date.
Late payments may incur a fee of 1.5% per month or the maximum allowed by law.
Client agrees to reimburse WCC Technologies Group for all reasonable costs incurred in the collection of unpaid balances.
4. Schedule and Working Hours
All work will be performed Monday through Friday, excluding holidays, during normal working hours (typically 8:00 AM to 5:00 PM local time), unless otherwise stated in the SOW. After-hours or weekend work may be subject to additional charges.
City of Vernon-Basement Quote #1_Rev2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 6
5. Change Orders
All changes to the scope of work must be made through a written and signed Change Order.
6. Warranties
WCC Technologies Group warrants that services will be performed in a professional and workmanlike manner. No other warranties, express or implied, are provided.
7. Limitation of Liability
The limitation on types and amounts of damages imposed by this section of the agreement shall not apply with respect to damages which arise or result from fraud, willful misconduct, or gross negligence of WCC Technologies Group, its affiliates or any subcontractor of WCC Technologies Group or its affiliates.
8. Confidentiality
Both parties agree to maintain the confidentiality of proprietary or confidential information disclosed during the course of this Agreement. This includes preliminary materials (e.g., draft SOWs, designs, budgets, technical concepts) provided for internal evaluation. Such materials may not be shared or reused without written consent. This duty survives termination of the Agreement.
9. Non-Solicitation
Neither party may solicit or hire the other party's employees or subcontractors during the term of this Agreement and for 12 months thereafter.
10. Force Majeure
Neither party shall be liable for delays or failure to perform due to causes beyond their reasonable control, including but not limited to natural disasters, strikes, shortages, supplier issues, or governmental actions.
11. Termination
Either party may terminate this Agreement or any SOW upon 30 days’ written notice.
Client agrees to pay for all services rendered and authorized expenses incurred prior to termination.
12. Intellectual Property
Unless otherwise specified in the SOW, WCC Technologies Group retains all rights to pre-existing intellectual property and tools used in the performance of services.
City of Vernon-Basement Quote #1_Rev2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 7
13. Governing Law and Dispute Resolution
This Agreement shall be governed by the laws of the State of California. Disputes exceeding $5,000 shall be resolved by binding arbitration in Los Angeles County, California, under the rules of the American Arbitration Association. Either party may seek injunctive relief in court if needed.
Signature
WCC Technologies Group
By: _______________________________
Name: Johnny Haygood
Title: President
Date: _______________________________
Client
By: _______________________________
Name: ____________________________
Title: _____________________________
Date: _______________________________
WCC Technologies2nd Authorized Signature:
___________________________________
Signature
___________________________________
Name
___________________________________
Title
___________________________________
Date
Approved as to Form:
_____________________________________
Zaynah Moussa-Milward, City Attorney
Attest:
_______________________________
Genoveva Rocha, City Clerk
Brian Saeki
City Administrator
your backbone for IT
Main Floor Quote #2 Revision_2
City of Vernon
Attn: Ernesto Smith
CMAS Agreement Number: 3-23-01-1017
Martin Phan
Technology Consultant
[email protected]
408.367.9452
City of Vernon-Main Floor Quote #2 Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 2
SCOPE OF WORK
Date: November 24, 2025
Quote: 25-704_Rev2
Provide labor and material to install access control hardware within customers Vernon facility.
Access Control Door:
Provide materials and labor to install new access control hardware to customer specified locations.
• Install (1ea) Verkada card reader to (7) locations.
• Install (1) Verkada intercom.
o WCC to use existing access control cabling at door locations. o WCC to terminate existing access control cabling onto new door controller. o WCC will provide back plates at all card reader locations • This quote assumes that WCC will utilize customer installed locks, REX, door contact, and transfer hinges.
Access Control Panel & Battery Installation:
• Install (2) Verkada AC42 to customer specified locations. • Install (1) Verkada 18AH Backup Battery
City of Vernon-Main Floor Quote #2 Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 3 Our Background and Company Story
WCC Technologies Group
WCC Technologies Group is a full-service technology integrator specializing in network infrastructure, physical security, collaboration systems, and IT solutions. Founded in 2003, we’ve built our reputation on delivering clean, reliable technology tailored to each client’s environment, budget, and timeline.
Headquartered in Southern California, we serve school districts, public agencies, and enterprise organizations that require dependable execution and responsive support. Our team holds active C7 (Low Voltage), C10 (Electrical), and C28 (Lock & Security Equipment) contractor licenses, enabling us to deliver fully integrated solutions with inhouse expertise across critical systems.
From structured cabling and wireless networks to surveillance, access control, and firerated backbone infrastructure, WCC Technologies Group manages every project with precision, safety, and long-term value in mind.
We recently changed our name from West Coast Cable to WCC Technologies Group to reflect our growth beyond cabling into complete end-to-end technology services.
While our name has evolved, our commitment to reliability, accountability, and client partnership remains unchanged.
What Sets Us Apart
• Turnkey technology solutions from cabling to IT systems • 20+ years of experience across education, enterprise, and government • Licensed C7, C10, and C28 contractor for complete in-house execution • Clean, professional installations built for long-term performance • Responsive, communicative project management
• Ongoing investment in people, training, and innovation At WCC Technologies Group, we combine technical expertise with a strong service culture. We’re building the go-to partner for organizations that value quality, consistency, and forward-thinking technology integration.
City of Vernon-Main Floor Quote #2 Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 4 Bill of materials - Pricing
Item Description Part Number Qty
Unit List
Price Extended List % Disc Total Price
HARDWARE
AC42 4 Door Controller AC42-HW 2 $1,799.00 $3,598.00 22% $2,806.44 18AH Backup Battery ACC-BAT-18AH 1 $699.00 $699.00 22% $545.22 AD34 Multi-format Card
Reader AD34-HW 7 $349.00 $2,443.00 22% $1,905.54
Intercom TD53 1 $1,799.00 $1,799.00 22% $1,403.22
SOFTWARE
3-Year Door License,
Capacity Increase LIC-AC-3Y-CAP 7 $599.00 $4,193.00 22% $3,270.54 3-Year Intercom License,
Capacity Increase LIC-TD-3Y-CAP 1 $1,049.00 $1,049.00 22% $818.22 Hardware $6,660.42
Software $4,088.76
Material $198.00
Labor $5,176.50
Sales Tax $720.13
Shipping $0.00
Total Project Price $16,843.81
City of Vernon-Main Floor Quote #2 Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 5
MASTER SERVICES AGREEMENT (MSA)
WCC Technologies Group
1. Scope of Work
WCC Technologies Group agrees to perform services as detailed in one or more projectspecific Statements of Work (SOWs). Each SOW will include a description of services, deliverables, pricing, timeline, and payment terms. Either party may serve as service provider or recipient under individual SOWs. All provisions of this Agreement apply equally regardless of which party issues the SOW.
Customer is responsible for all costs associated with permits, easements, and/or rights-ofway.
2. Term
This Agreement shall begin on the date it is signed by all parties and shall remain in effect for one (1) year from that date.
3. Payment Terms
Client agrees to pay WCC Technologies Group according to the following project milestones, unless otherwise specified in the applicable Statement of Work (SOW):
• 50% due upon signing contract
• 40% due on delivery of equipment
• 10% due at completion of project
Invoices are due Net 30 from the date of invoice.
A 2% discount will be applied to invoices paid within 15 calendar days of the invoice date.
Late payments may incur a fee of 1.5% per month or the maximum allowed by law.
Client agrees to reimburse WCC Technologies Group for all reasonable costs incurred in the collection of unpaid balances.
4. Schedule and Working Hours
All work will be performed Monday through Friday, excluding holidays, during normal working hours (typically 8:00 AM to 5:00 PM local time), unless otherwise stated in the SOW. After-hours or weekend work may be subject to additional charges.
City of Vernon-Main Floor Quote #2 Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 6
5. Change Orders
All changes to the scope of work must be made through a written and signed Change Order.
6. Warranties
WCC Technologies Group warrants that services will be performed in a professional and workmanlike manner. No other warranties, express or implied, are provided.
7. Limitation of Liability
The limitation on types and amounts of damages imposed by this section of the agreement shall not apply with respect to damages which arise or result from fraud, willful misconduct, or gross negligence of WCC Technologies Group, its affiliates or any subcontractor of WCC Technologies Group or its affiliates.
8. Confidentiality
Both parties agree to maintain the confidentiality of proprietary or confidential information disclosed during the course of this Agreement. This includes preliminary materials (e.g., draft SOWs, designs, budgets, technical concepts) provided for internal evaluation. Such materials may not be shared or reused without written consent. This duty survives termination of the Agreement.
9. Non-Solicitation
Neither party may solicit or hire the other party's employees or subcontractors during the term of this Agreement and for 12 months thereafter.
10. Force Majeure
Neither party shall be liable for delays or failure to perform due to causes beyond their reasonable control, including but not limited to natural disasters, strikes, shortages, supplier issues, or governmental actions.
11. Termination
Either party may terminate this Agreement or any SOW upon 30 days’ written notice.
Client agrees to pay for all services rendered and authorized expenses incurred prior to termination.
12. Intellectual Property
Unless otherwise specified in the SOW, WCC Technologies Group retains all rights to pre-existing intellectual property and tools used in the performance of services.
City of Vernon-Main Floor Quote #2 Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 7
13. Governing Law and Dispute Resolution
This Agreement shall be governed by the laws of the State of California. Disputes exceeding $5,000 shall be resolved by binding arbitration in Los Angeles County, California, under the rules of the American Arbitration Association. Either party may seek injunctive relief in court if needed.
Signature
WCC Technologies Group
By: _______________________________
Name: Johnny Haygood
Title: President
Date: _______________________________
Client
By: _______________________________
Name: ____________________________
Title: _____________________________
Date: _______________________________
Approved as to Form:
_____________________________________
Zaynah Moussa-Milward, City Attorney
Attest:
_______________________________
Genoveva Rocha, City Clerk
WCC Technologies2nd Authorized Signature:
___________________________________
Signature
___________________________________
Name
___________________________________
Title
___________________________________
Date
Brian Saeki
City Administrator
your backbone for IT
2nd Floor Quote #3 Revision 2
City of Vernon
Attn: Ernesto Smith
CMAS Agreement Number: 3-23-01-1017
Martin Phan
Technology Consultant
[email protected]
408.367.9452
City of Vernon-2nd Floor Quote #3_Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 2
SCOPE OF WORK
Date: November 24, 2025
Quote: 25-705_Rev2
Provide labor and material to install access control hardware within customers Vernon facility.
Access Control Door:
Provide materials and labor to install new access control hardware to customer specified locations.
• Install (1ea) Verkada card reader to (18) locations.
• Install (9) Verkada intercom.
o WCC to use existing access control cabling at door locations. o WCC to terminate existing access control cabling onto new door controller. o WCC will provide back plates at all card reader locations • Install 18/4 Awg cable to intercom #1 & #8
• Install 18/4 Awg cable to card reader #1 & #3
o Customer to install network bridges and pathway
• This quote assumes that WCC will utilize customer installed locks, REX, door contact, and transfer hinges.
• Provide (1) Verkada 3-year door license to monitor (1) door.
Access Control Panel Installation:
• Install (2) Verkada AC62 to customer specified locations. • Install (2) Verkada 18AH Backup Battery
City of Vernon-2nd Floor Quote #3_Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 3 Our Background and Company Story
WCC Technologies Group
WCC Technologies Group is a full-service technology integrator specializing in network infrastructure, physical security, collaboration systems, and IT solutions. Founded in 2003, we’ve built our reputation on delivering clean, reliable technology tailored to each client’s environment, budget, and timeline.
Headquartered in Southern California, we serve school districts, public agencies, and enterprise organizations that require dependable execution and responsive support. Our team holds active C7 (Low Voltage), C10 (Electrical), and C28 (Lock & Security Equipment) contractor licenses, enabling us to deliver fully integrated solutions with inhouse expertise across critical systems.
From structured cabling and wireless networks to surveillance, access control, and firerated backbone infrastructure, WCC Technologies Group manages every project with precision, safety, and long-term value in mind.
We recently changed our name from West Coast Cable to WCC Technologies Group to reflect our growth beyond cabling into complete end-to-end technology services.
While our name has evolved, our commitment to reliability, accountability, and client partnership remains unchanged.
What Sets Us Apart
• Turnkey technology solutions from cabling to IT systems • 20+ years of experience across education, enterprise, and government • Licensed C7, C10, and C28 contractor for complete in-house execution • Clean, professional installations built for long-term performance • Responsive, communicative project management
• Ongoing investment in people, training, and innovation At WCC Technologies Group, we combine technical expertise with a strong service culture. We’re building the go-to partner for organizations that value quality, consistency, and forward-thinking technology integration.
City of Vernon-2nd Floor Quote #3_Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 4 Bill of materials - Pricing
Item Description Part Number Qty
Unit List
Price
Extended
List
%
Disc
Total
Price
HARDWARE
AC62 16 Door Controller AC62-HW 2 $5,299.00 $10,598.00 22% $8,266.44 18AH Backup Battery ACC-BAT-18AH 2 $699.00 $1,398.00 22% $1,090.44 AD34 Multi-format Card Reader AD34-HW 18 $349.00 $6,282.00 22% $4,899.96 BR12 Wired Surface Mount Door
Contact, 5 Pack BR12-HW 1 $99.00 $99.00 22% $77.22
TD53 Intercom TD53-HW 9 $1,799.00 $16,191.00 22% $12,628.98
SOFTWARE
3-Year Door License, Capacity
Increase LIC-AC-3Y-CAP 18 $599.00 $10,782.00 22% $8,409.96 3-Year Intercom License, Capacity
Increase LIC-TD-3Y-CAP 9 $1,049.00 $9,441.00 22% $7,363.98 Hardware $26,963.04
Software $15,773.94
Material $722.04
Labor $18,207.00
Sales Tax $2,906.93
Shipping $0.00
Total Project Price $64,572.95
City of Vernon-2nd Floor Quote #3_Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 5
MASTER SERVICES AGREEMENT (MSA)
WCC Technologies Group
1. Scope of Work
WCC Technologies Group agrees to perform services as detailed in one or more projectspecific Statements of Work (SOWs). Each SOW will include a description of services, deliverables, pricing, timeline, and payment terms. Either party may serve as service provider or recipient under individual SOWs. All provisions of this Agreement apply equally regardless of which party issues the SOW.
Customer is responsible for all costs associated with permits, easements, and/or rights-ofway.
2. Term
This Agreement shall begin on the date it is signed by all parties and shall remain in effect for one (1) year from that date.
3. Payment Terms
Client agrees to pay WCC Technologies Group according to the following project milestones, unless otherwise specified in the applicable Statement of Work (SOW):
• 50% due upon signing contract
• 40% due on delivery of equipment
• 10% due at completion of project
Invoices are due Net 30 from the date of invoice.
A 2% discount will be applied to invoices paid within 15 calendar days of the invoice date.
Late payments may incur a fee of 1.5% per month or the maximum allowed by law.
Client agrees to reimburse WCC Technologies Group for all reasonable costs incurred in the collection of unpaid balances.
4. Schedule and Working Hours
All work will be performed Monday through Friday, excluding holidays, during normal working hours (typically 8:00 AM to 5:00 PM local time), unless otherwise stated in the SOW. After-hours or weekend work may be subject to additional charges.
City of Vernon-2nd Floor Quote #3_Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 6
5. Change Orders
All changes to the scope of work must be made through a written and signed Change Order.
6. Warranties
WCC Technologies Group warrants that services will be performed in a professional and workmanlike manner. No other warranties, express or implied, are provided.
7. Limitation of Liability
The limitation on types and amounts of damages imposed by this section of the agreement shall not apply with respect to damages which arise or result from fraud, willful misconduct, or gross negligence of WCC Technologies Group, its affiliates or any subcontractor of WCC Technologies Group or its affiliates.
8. Confidentiality
Both parties agree to maintain the confidentiality of proprietary or confidential information disclosed during the course of this Agreement. This includes preliminary materials (e.g., draft SOWs, designs, budgets, technical concepts) provided for internal evaluation. Such materials may not be shared or reused without written consent. This duty survives termination of the Agreement.
9. Non-Solicitation
Neither party may solicit or hire the other party's employees or subcontractors during the term of this Agreement and for 12 months thereafter.
10. Force Majeure
Neither party shall be liable for delays or failure to perform due to causes beyond their reasonable control, including but not limited to natural disasters, strikes, shortages, supplier issues, or governmental actions.
11. Termination
Either party may terminate this Agreement or any SOW upon 30 days’ written notice.
Client agrees to pay for all services rendered and authorized expenses incurred prior to termination.
12. Intellectual Property
Unless otherwise specified in the SOW, WCC Technologies Group retains all rights to pre-existing intellectual property and tools used in the performance of services.
City of Vernon-2nd Floor Quote #3_Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 7
13. Governing Law and Dispute Resolution
This Agreement shall be governed by the laws of the State of California. Disputes exceeding $5,000 shall be resolved by binding arbitration in Los Angeles County, California, under the rules of the American Arbitration Association. Either party may seek injunctive relief in court if needed.
Signature
WCC Technologies Group
By: _______________________________
Name: Johnny Haygood
Title: President
Date: _______________________________
Client
By: _______________________________
Name: ____________________________
Title: _____________________________
Date: _______________________________
Brian Saeki
City Administrator
WCC Technologies2nd Authorized Signature:
___________________________________
Signature
___________________________________
Name
___________________________________
Title
___________________________________
Date
Approved as to Form:
_____________________________________
Zaynah Moussa-Milward, City Attorney
Attest:
_______________________________
Genoveva Rocha, City Clerk
your backbone for IT
3rd Floor Quote #4 Revision 2 (Equipment Only)
City of Vernon
Attn: Ernesto Smith
CMAS Agreement Number: 3-23-01-1017
Martin Phan
Technology Consultant
[email protected]
408.367.9452
#25820
City of Vernon-3rd Floor Quote #4 Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 2
SCOPE OF WORK
Date: August 28, 2025
Quote: 25-706_Rev2
Provide material to install access control hardware within customers Vernon facility.
Verkada Equipment:
• Drop ship the following equipment to the City of Vernon:
Bill of materials - Pricing
Item Description Part Number Qty
Unit List
Price
Extended
List % Disc Total Price
HARDWARE
AC42 4 Door Controller AC42-HW 1 $1,799.00 $1,799.00 22% $1,403.22 18AH Backup Battery ACC-BAT-18AH 1 $699.00 $699.00 22% $545.22 AD34 Multi-format Card
Reader AD34-HW 4 $349.00 $1,396.00 22% $1,088.88
BR12 Wired Surface Mount
Door Contact, 5 Pack BR12-HW 1 $99.00 $99.00 22% $77.22
SOFTWARE
3-Year Door License,
Capacity Increase LIC-AC-3Y-CAP 5 $599.00 $2,995.00 22% $2,336.10 Hardware $3,114.54
Software $2,336.10
Material $165.00
Labor $0.00
Sales Tax $344.35
Shipping $0.00
Total Project Price $5,959.99
#25820
City of Vernon-3rd Floor Quote #4 Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 3 Our Background and Company Story
WCC Technologies Group
WCC Technologies Group is a full-service technology integrator specializing in network infrastructure, physical security, collaboration systems, and IT solutions. Founded in 2003, we’ve built our reputation on delivering clean, reliable technology tailored to each client’s environment, budget, and timeline.
Headquartered in Southern California, we serve school districts, public agencies, and enterprise organizations that require dependable execution and responsive support. Our team holds active C7 (Low Voltage), C10 (Electrical), and C28 (Lock & Security Equipment) contractor licenses, enabling us to deliver fully integrated solutions with inhouse expertise across critical systems.
From structured cabling and wireless networks to surveillance, access control, and firerated backbone infrastructure, WCC Technologies Group manages every project with precision, safety, and long-term value in mind.
We recently changed our name from West Coast Cable to WCC Technologies Group to reflect our growth beyond cabling into complete end-to-end technology services.
While our name has evolved, our commitment to reliability, accountability, and client partnership remains unchanged.
What Sets Us Apart
• Turnkey technology solutions from cabling to IT systems • 20+ years of experience across education, enterprise, and government • Licensed C7, C10, and C28 contractor for complete in-house execution • Clean, professional installations built for long-term performance • Responsive, communicative project management
• Ongoing investment in people, training, and innovation At WCC Technologies Group, we combine technical expertise with a strong service culture. We’re building the go-to partner for organizations that value quality, consistency, and forward-thinking technology integration.
#25820
City of Vernon-3rd Floor Quote #4 Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 4
MASTER SERVICES AGREEMENT (MSA)
WCC Technologies Group
1. Scope of Work
WCC Technologies Group agrees to perform services as detailed in one or more projectspecific Statements of Work (SOWs). Each SOW will include a description of services, deliverables, pricing, timeline, and payment terms. Either party may serve as service provider or recipient under individual SOWs. All provisions of this Agreement apply equally regardless of which party issues the SOW.
Customer is responsible for all costs associated with permits, easements, and/or rights-ofway.
2. Term
This Agreement shall begin on the date it is signed by all parties and shall remain in effect for one (1) year from that date.
3. Payment Terms
Client agrees to pay WCC Technologies Group according to the following project milestones, unless otherwise specified in the applicable Statement of Work (SOW):
• 50% due upon signing contract
• 40% due on delivery of equipment
• 10% due at completion of project
Invoices are due Net 30 from the date of invoice.
A 2% discount will be applied to invoices paid within 15 calendar days of the invoice date.
Late payments may incur a fee of 1.5% per month or the maximum allowed by law.
Client agrees to reimburse WCC Technologies Group for all reasonable costs incurred in the collection of unpaid balances.
4. Schedule and Working Hours
All work will be performed Monday through Friday, excluding holidays, during normal working hours (typically 8:00 AM to 5:00 PM local time), unless otherwise stated in the SOW. After-hours or weekend work may be subject to additional charges. #25820
City of Vernon-3rd Floor Quote #4 Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 5
5. Change Orders
All changes to the scope of work must be made through a written and signed Change Order.
6. Warranties
WCC Technologies Group warrants that services will be performed in a professional and workmanlike manner. No other warranties, express or implied, are provided.
7. Limitation of Liability
WCC Technologies Group’s total liability for any claim shall not exceed the total fees paid by Client under the applicable SOW. Neither party shall be liable for incidental, special, or consequential damages. Claims must be brought within 6 months of the event giving rise to the claim.
The limitation on types and amounts of damages imposed by this section of the agreement shall not apply with respect to damages which arise or result from fraud, willful misconduct, or gross negligence of WCC Technologies Group, its affiliates or any subcontractor of WCC Technologies Group or its affiliates.
8. Confidentiality
Both parties agree to maintain the confidentiality of proprietary or confidential information disclosed during the course of this Agreement. This includes preliminary materials (e.g., draft SOWs, designs, budgets, technical concepts) provided for internal evaluation. Such materials may not be shared or reused without written consent. This duty survives termination of the Agreement.
9. Non-Solicitation
Neither party may solicit or hire the other party's employees or subcontractors during the term of this Agreement and for 12 months thereafter.
10. Force Majeure
Neither party shall be liable for delays or failure to perform due to causes beyond their reasonable control, including but not limited to natural disasters, strikes, shortages, supplier issues, or governmental actions.
11. Termination
Either party may terminate this Agreement or any SOW upon 30 days’ written notice.
Client agrees to pay for all services rendered and authorized expenses incurred prior to termination.
12. Intellectual Property
Unless otherwise specified in the SOW, WCC Technologies Group retains all rights to pre-existing intellectual property and tools used in the performance of services. #25820
City of Vernon-3rd Floor Quote #4 Revision 2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 6
13. Governing Law and Dispute Resolution
This Agreement shall be governed by the laws of the State of California. Disputes exceeding $5,000 shall be resolved by binding arbitration in Los Angeles County, California, under the rules of the American Arbitration Association. Either party may seek injunctive relief in court if needed.
Signature
WCC Technologies Group
By: _______________________________
Name: Johnny Haygood
Title: President
Date: _______________________________
Client
By: _______________________________
Name: ____________________________
Title: _____________________________
Date: _______________________________
Approved as to Form:
_____________________________________
Zaynah Moussa-Milward, City Attorney
Attest:
_______________________________
Genoveva Rocha, City Clerk
WCC Technologies2nd Authorized Signature:
___________________________________
Signature
___________________________________
Name
___________________________________
Title
___________________________________
Date
Brian Saeki
City Administrator
your backbone for IT
Power Plant Quote #5_Revision_2
City of Vernon
Attn: Ernesto Smith
CMAS Agreement Number: 3-23-01-1017
Martin Phan
Technology Consultant
[email protected]
408.367.9452
City of Vernon-Power Plant Quote #5_Rev_2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 2
SCOPE OF WORK
Date: November 24, 2025
Quote: 25-707_Rev_2
Provide labor and material to install access control hardware within customers Vernon facility.
Access Control Door:
Provide materials and labor to install new access control hardware to customer specified locations.
• Install (1ea) Verkada card reader to (14) locations.
• Install (13) Verkada intercom.
o WCC to use existing access control cabling at door locations. o WCC to terminate existing access control cabling onto new door controller. o WCC will provide back plates at all card reader locations • WCC will provide 3-YR licenses for all Verkada equipment. • This quote assumes that WCC will utilize customer installed locks, REX, door contact, and transfer hinges.
Access Control Panel Installation:
• Install (1) Verkada AC62 to customer specified locations. • Install (1) Verkada 18AH Backup Battery
iPad and Stand
• Install (1) iPad to customer specified location
• Install (1) iPad stand to customer specified location • Provide (1) 3-YR desk station license for iPad.
City of Vernon-Power Plant Quote #5_Rev_2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 3 Our Background and Company Story
WCC Technologies Group
WCC Technologies Group is a full-service technology integrator specializing in network infrastructure, physical security, collaboration systems, and IT solutions. Founded in 2003, we’ve built our reputation on delivering clean, reliable technology tailored to each client’s environment, budget, and timeline.
Headquartered in Southern California, we serve school districts, public agencies, and enterprise organizations that require dependable execution and responsive support. Our team holds active C7 (Low Voltage), C10 (Electrical), and C28 (Lock & Security Equipment) contractor licenses, enabling us to deliver fully integrated solutions with inhouse expertise across critical systems.
From structured cabling and wireless networks to surveillance, access control, and firerated backbone infrastructure, WCC Technologies Group manages every project with precision, safety, and long-term value in mind.
We recently changed our name from West Coast Cable to WCC Technologies Group to reflect our growth beyond cabling into complete end-to-end technology services.
While our name has evolved, our commitment to reliability, accountability, and client partnership remains unchanged.
What Sets Us Apart
• Turnkey technology solutions from cabling to IT systems • 20+ years of experience across education, enterprise, and government • Licensed C7, C10, and C28 contractor for complete in-house execution • Clean, professional installations built for long-term performance • Responsive, communicative project management
• Ongoing investment in people, training, and innovation At WCC Technologies Group, we combine technical expertise with a strong service culture. We’re building the go-to partner for organizations that value quality, consistency, and forward-thinking technology integration.
City of Vernon-Power Plant Quote #5_Rev_2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 4 Bill of materials - Pricing
Item Description Part Number Qty
Unit List
Price
Extended
List
%
Disc Total Price
HARDWARE
AC62 16 Door Controller AC62-HW 1 $5,299.00 $5,299.00 22% $4,133.22 18AH Backup Battery ACC-BAT-18AH 1 $699.00 $699.00 22% $545.22 AD34 Multi-format Card Reader AD34-HW 14 $349.00 $4,886.00 22% $3,811.08 TD53 Intercom TD53-HW 13 $1,799.00 $23,387.00 22% $18,241.86
SOFTWARE
3-Year Door License, Capacity
Increase LIC-AC-3Y-CAP 14 $599.00 $8,386.00 22% $6,541.08 3-Year Desk Station License,
Capacity Increase LIC-TX-3Y-CAP 1 $749.00 $749.00 22% $584.22 3-Year Intercom License,
Capacity Increase LIC-TD-3Y-CAP 13 $1,049.00 $13,637.00 22% $10,636.86
SERVICES
iPad 1 $510.51 $510.51 $510.51
iPad Stand 1 $335.48 $335.48 $335.48
Hardware $26,731.38
Software $17,762.16
Material $1,227.60
Labor $15,886.50
Sales Tax $2,935.69
Shipping $0.00
Total Project Price $64,543.33
City of Vernon-Power Plant Quote #5_Rev_2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 5
MASTER SERVICES AGREEMENT (MSA)
WCC Technologies Group
1. Scope of Work
WCC Technologies Group agrees to perform services as detailed in one or more projectspecific Statements of Work (SOWs). Each SOW will include a description of services, deliverables, pricing, timeline, and payment terms. Either party may serve as service provider or recipient under individual SOWs. All provisions of this Agreement apply equally regardless of which party issues the SOW.
Customer is responsible for all costs associated with permits, easements, and/or rights-ofway.
2. Term
This Agreement shall begin on the date it is signed by all parties and shall remain in effect for one (1) year from that date.
3. Payment Terms
Client agrees to pay WCC Technologies Group according to the following project milestones, unless otherwise specified in the applicable Statement of Work (SOW):
• 50% due upon signing contract
• 40% due on delivery of equipment
• 10% due at completion of project
Invoices are due Net 30 from the date of invoice.
A 2% discount will be applied to invoices paid within 15 calendar days of the invoice date.
Late payments may incur a fee of 1.5% per month or the maximum allowed by law.
Client agrees to reimburse WCC Technologies Group for all reasonable costs incurred in the collection of unpaid balances.
4. Schedule and Working Hours
All work will be performed Monday through Friday, excluding holidays, during normal working hours (typically 8:00 AM to 5:00 PM local time), unless otherwise stated in the SOW. After-hours or weekend work may be subject to additional charges.
City of Vernon-Power Plant Quote #5_Rev_2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 6
5. Change Orders
All changes to the scope of work must be made through a written and signed Change Order.
6. Warranties
WCC Technologies Group warrants that services will be performed in a professional and workmanlike manner. No other warranties, express or implied, are provided.
7. Limitation of Liability
The limitation on types and amounts of damages imposed by this section of the agreement shall not apply with respect to damages which arise or result from fraud, willful misconduct, or gross negligence of WCC Technologies Group, its affiliates or any subcontractor of WCC Technologies Group or its affiliates.
8. Confidentiality
Both parties agree to maintain the confidentiality of proprietary or confidential information disclosed during the course of this Agreement. This includes preliminary materials (e.g., draft SOWs, designs, budgets, technical concepts) provided for internal evaluation. Such materials may not be shared or reused without written consent. This duty survives termination of the Agreement.
9. Non-Solicitation
Neither party may solicit or hire the other party's employees or subcontractors during the term of this Agreement and for 12 months thereafter.
10. Force Majeure
Neither party shall be liable for delays or failure to perform due to causes beyond their reasonable control, including but not limited to natural disasters, strikes, shortages, supplier issues, or governmental actions.
11. Termination
Either party may terminate this Agreement or any SOW upon 30 days’ written notice.
Client agrees to pay for all services rendered and authorized expenses incurred prior to termination.
12. Intellectual Property
Unless otherwise specified in the SOW, WCC Technologies Group retains all rights to pre-existing intellectual property and tools used in the performance of services.
City of Vernon-Power Plant Quote #5_Rev_2 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 7
13. Governing Law and Dispute Resolution
This Agreement shall be governed by the laws of the State of California. Disputes exceeding $5,000 shall be resolved by binding arbitration in Los Angeles County, California, under the rules of the American Arbitration Association. Either party may seek injunctive relief in court if needed.
Signature
WCC Technologies Group
By: _______________________________
Name: Johnny Haygood
Title: President
Date: _______________________________
Client
By: _______________________________
Name: ____________________________
Title: _____________________________
Date: _______________________________
WCC Technologies2nd Authorized Signature:
___________________________________
Signature
___________________________________
Name
___________________________________
Title
___________________________________
Date
Approved as to Form:
_____________________________________
Zaynah Moussa-Milward, City Attorney
Attest:
_______________________________
Genoveva Rocha, City Clerk
Brian Saeki
City Administrator
your backbone for IT
Fire station Quote #6
City of Vernon
Attn: Ernesto Smith
CMAS Agreement Number: 3-23-01-1017
Martin Phan
Technology Consultant
[email protected]
408.367.9452
City of Vernon-Fire station Quote #6 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 2
SCOPE OF WORK
Date: November 24, 2025
Quote: 25-708
Provide labor and material to install access control hardware within customers Vernon facility.
Access Control Door:
Provide materials and labor to install new access control hardware to customer specified locations.
• Install (1ea) Verkada card reader to (2) locations.
o WCC to use existing access control cabling at door locations. o WCC to terminate existing access control cabling onto new door controller. o WCC will provide back plates at all card reader locations • This quote assumes that WCC will utilize customer installed locks, REX, door contact, and transfer hinges.
Access Control Panel Installation:
• Install (1) Verkada AC42 to customer specified locations. • Install (1) Verkada 4AH Backup Battery
City of Vernon-Fire station Quote #6 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 3 Our Background and Company Story
WCC Technologies Group
WCC Technologies Group is a full-service technology integrator specializing in network infrastructure, physical security, collaboration systems, and IT solutions. Founded in 2003, we’ve built our reputation on delivering clean, reliable technology tailored to each client’s environment, budget, and timeline.
Headquartered in Southern California, we serve school districts, public agencies, and enterprise organizations that require dependable execution and responsive support. Our team holds active C7 (Low Voltage), C10 (Electrical), and C28 (Lock & Security Equipment) contractor licenses, enabling us to deliver fully integrated solutions with inhouse expertise across critical systems.
From structured cabling and wireless networks to surveillance, access control, and firerated backbone infrastructure, WCC Technologies Group manages every project with precision, safety, and long-term value in mind.
We recently changed our name from West Coast Cable to WCC Technologies Group to reflect our growth beyond cabling into complete end-to-end technology services.
While our name has evolved, our commitment to reliability, accountability, and client partnership remains unchanged.
What Sets Us Apart
• Turnkey technology solutions from cabling to IT systems • 20+ years of experience across education, enterprise, and government • Licensed C7, C10, and C28 contractor for complete in-house execution • Clean, professional installations built for long-term performance • Responsive, communicative project management
• Ongoing investment in people, training, and innovation At WCC Technologies Group, we combine technical expertise with a strong service culture. We’re building the go-to partner for organizations that value quality, consistency, and forward-thinking technology integration.
City of Vernon-Fire station Quote #6 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 4 Bill of materials - Pricing
Item Description Part Number Qty
Unit List
Price
Extended
List
%
Disc
Total
Price
HARDWARE
AC42 4 Door Controller AC42-HW 1 $1,799.00 $1,799.00 22% $1,403.22 4AH Backup Battery ACC-BAT-4AH 1 $129.00 $129.00 22% $100.62 AD34 Multi-format Card
Reader AD34-HW 2 $349.00 $698.00 22% $544.44
SOFTWARE
3-Year Door License,
Capacity Increase LIC-AC-3Y-CAP 2 $599.00 $1,198.00 22% $934.44 Hardware $2,048.28
Software $934.44
Material $66.00
Labor $2,499.00
Sales Tax $222.00
Shipping $0.00
Total Project Price $5,769.72
City of Vernon-Fire station Quote #6 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 5
MASTER SERVICES AGREEMENT (MSA)
WCC Technologies Group
1. Scope of Work
WCC Technologies Group agrees to perform services as detailed in one or more projectspecific Statements of Work (SOWs). Each SOW will include a description of services, deliverables, pricing, timeline, and payment terms. Either party may serve as service provider or recipient under individual SOWs. All provisions of this Agreement apply equally regardless of which party issues the SOW.
Customer is responsible for all costs associated with permits, easements, and/or rights-ofway.
2. Term
This Agreement shall begin on the date it is signed by all parties and shall remain in effect for one (1) year from that date.
3. Payment Terms
Client agrees to pay WCC Technologies Group according to the following project milestones, unless otherwise specified in the applicable Statement of Work (SOW):
• 50% due upon signing contract
• 40% due on delivery of equipment
• 10% due at completion of project
Invoices are due Net 30 from the date of invoice.
A 2% discount will be applied to invoices paid within 15 calendar days of the invoice date.
Late payments may incur a fee of 1.5% per month or the maximum allowed by law.
Client agrees to reimburse WCC Technologies Group for all reasonable costs incurred in the collection of unpaid balances.
4. Schedule and Working Hours
All work will be performed Monday through Friday, excluding holidays, during normal working hours (typically 8:00 AM to 5:00 PM local time), unless otherwise stated in the SOW. After-hours or weekend work may be subject to additional charges.
City of Vernon-Fire station Quote #6 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 6
5. Change Orders
All changes to the scope of work must be made through a written and signed Change Order.
6. Warranties
WCC Technologies Group warrants that services will be performed in a professional and workmanlike manner. No other warranties, express or implied, are provided.
7. Limitation of Liability
The limitation on types and amounts of damages imposed by this section of the agreement shall not apply with respect to damages which arise or result from fraud, willful misconduct, or gross negligence of WCC Technologies Group, its affiliates or any subcontractor of WCC Technologies Group or its affiliates.
8. Confidentiality
Both parties agree to maintain the confidentiality of proprietary or confidential information disclosed during the course of this Agreement. This includes preliminary materials (e.g., draft SOWs, designs, budgets, technical concepts) provided for internal evaluation. Such materials may not be shared or reused without written consent. This duty survives termination of the Agreement.
9. Non-Solicitation
Neither party may solicit or hire the other party's employees or subcontractors during the term of this Agreement and for 12 months thereafter.
10. Force Majeure
Neither party shall be liable for delays or failure to perform due to causes beyond their reasonable control, including but not limited to natural disasters, strikes, shortages, supplier issues, or governmental actions.
11. Termination
Either party may terminate this Agreement or any SOW upon 30 days’ written notice.
Client agrees to pay for all services rendered and authorized expenses incurred prior to termination.
12. Intellectual Property
Unless otherwise specified in the SOW, WCC Technologies Group retains all rights to pre-existing intellectual property and tools used in the performance of services.
City of Vernon-Fire station Quote #6 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 7
13. Governing Law and Dispute Resolution
This Agreement shall be governed by the laws of the State of California. Disputes exceeding $5,000 shall be resolved by binding arbitration in Los Angeles County, California, under the rules of the American Arbitration Association. Either party may seek injunctive relief in court if needed.
Signature
WCC Technologies Group
By: _______________________________
Name: Johnny Haygood
Title: President
Date: _______________________________
Client
By: _______________________________
Name: ____________________________
Title: _____________________________
Date: _______________________________
Approved as to Form:
_________________________________
Zaynah Moussa-Milward, City Attorney
Attest:
_______________________________
Genoveva Rocha, City Clerk
WCC Technologies2nd Authorized Signature:
___________________________________
Signature
___________________________________
Name
___________________________________
Title
___________________________________
Date
Brian Saeki
City Administrator
your backbone for IT
First Phase Camera’s Quote #7
City of Vernon
Attn: Ernesto Smith
CMAS Agreement Number: 3-23-01-1017
Martin Phan
Technology Consultant
[email protected]
408.367.9452
City of Vernon-First Phase Cameras Quote #7 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 2
SCOPE OF WORK
Date: November 24, 2025
Quote: 25-709
Provide labor and material to install cameras within customers Vernon facility.
Camera Install:
Provide labor to install new cameras to customer specified locations. • Install (1ea) customer provided Verkada CD43 cameras to (6) locations. o WCC to use existing cabling at camera locations.
• This quote assumes that customer will install and program camera’s City of Vernon-First Phase Cameras Quote #7 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 3 Our Background and Company Story
WCC Technologies Group
WCC Technologies Group is a full-service technology integrator specializing in network infrastructure, physical security, collaboration systems, and IT solutions. Founded in 2003, we’ve built our reputation on delivering clean, reliable technology tailored to each client’s environment, budget, and timeline.
Headquartered in Southern California, we serve school districts, public agencies, and enterprise organizations that require dependable execution and responsive support. Our team holds active C7 (Low Voltage), C10 (Electrical), and C28 (Lock & Security Equipment) contractor licenses, enabling us to deliver fully integrated solutions with inhouse expertise across critical systems.
From structured cabling and wireless networks to surveillance, access control, and firerated backbone infrastructure, WCC Technologies Group manages every project with precision, safety, and long-term value in mind.
We recently changed our name from West Coast Cable to WCC Technologies Group to reflect our growth beyond cabling into complete end-to-end technology services.
While our name has evolved, our commitment to reliability, accountability, and client partnership remains unchanged.
What Sets Us Apart
• Turnkey technology solutions from cabling to IT systems • 20+ years of experience across education, enterprise, and government • Licensed C7, C10, and C28 contractor for complete in-house execution • Clean, professional installations built for long-term performance • Responsive, communicative project management
• Ongoing investment in people, training, and innovation At WCC Technologies Group, we combine technical expertise with a strong service culture. We’re building the go-to partner for organizations that value quality, consistency, and forward-thinking technology integration.
City of Vernon-First Phase Cameras Quote #7 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 4 Bill of materials - Pricing
Item Description Part Number Qty
Unit List
Price
Extended
List
%
Disc
Total
Price
HARDWARE
CD43 Indoor Dome Camera,
256GB, 30 Days Max CD43-256-HW 6 $999.00 $5,994.00 22% $4,675.32
SOFTWARE
3-Year Camera License,
Capacity Increase LIC-CAM-3Y-CAP 6 $549.00 $3,294.00 22% $2,569.32 Hardware $4,675.32
Software $2,569.32
Material $0.00
Labor $1,071.00
Sales Tax $490.91
Shipping $0.00
Total Project Price $8,806.55
City of Vernon-First Phase Cameras Quote #7 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 5
MASTER SERVICES AGREEMENT (MSA)
WCC Technologies Group
1. Scope of Work
WCC Technologies Group agrees to perform services as detailed in one or more projectspecific Statements of Work (SOWs). Each SOW will include a description of services, deliverables, pricing, timeline, and payment terms. Either party may serve as service provider or recipient under individual SOWs. All provisions of this Agreement apply equally regardless of which party issues the SOW.
Customer is responsible for all costs associated with permits, easements, and/or rights-ofway.
2. Term
This Agreement shall begin on the date it is signed by all parties and shall remain in effect for one (1) year from that date.
3. Payment Terms
Client agrees to pay WCC Technologies Group according to the following project milestones, unless otherwise specified in the applicable Statement of Work (SOW):
• 50% due upon signing contract
• 40% due on delivery of equipment
• 10% due at completion of project
Invoices are due Net 30 from the date of invoice.
A 2% discount will be applied to invoices paid within 15 calendar days of the invoice date.
Late payments may incur a fee of 1.5% per month or the maximum allowed by law.
Client agrees to reimburse WCC Technologies Group for all reasonable costs incurred in the collection of unpaid balances.
4. Schedule and Working Hours
All work will be performed Monday through Friday, excluding holidays, during normal working hours (typically 8:00 AM to 5:00 PM local time), unless otherwise stated in the SOW. After-hours or weekend work may be subject to additional charges.
City of Vernon-First Phase Cameras Quote #7 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 6
5. Change Orders
All changes to the scope of work must be made through a written and signed Change Order.
6. Warranties
WCC Technologies Group warrants that services will be performed in a professional and workmanlike manner. No other warranties, express or implied, are provided.
7. Limitation of Liability
The limitation on types and amounts of damages imposed by this section of the agreement shall not apply with respect to damages which arise or result from fraud, willful misconduct, or gross negligence of WCC Technologies Group, its affiliates or any subcontractor of WCC Technologies Group or its affiliates.
8. Confidentiality
Both parties agree to maintain the confidentiality of proprietary or confidential information disclosed during the course of this Agreement. This includes preliminary materials (e.g., draft SOWs, designs, budgets, technical concepts) provided for internal evaluation. Such materials may not be shared or reused without written consent. This duty survives termination of the Agreement.
9. Non-Solicitation
Neither party may solicit or hire the other party's employees or subcontractors during the term of this Agreement and for 12 months thereafter.
10. Force Majeure
Neither party shall be liable for delays or failure to perform due to causes beyond their reasonable control, including but not limited to natural disasters, strikes, shortages, supplier issues, or governmental actions.
11. Termination
Either party may terminate this Agreement or any SOW upon 30 days’ written notice.
Client agrees to pay for all services rendered and authorized expenses incurred prior to termination.
12. Intellectual Property
Unless otherwise specified in the SOW, WCC Technologies Group retains all rights to pre-existing intellectual property and tools used in the performance of services.
City of Vernon-First Phase Cameras Quote #7 California Contractor # 819788 WCC Technologies Group | your backbone for IT | wcctechgroup.com | (909) 364-9906 Page 7
13. Governing Law and Dispute Resolution
This Agreement shall be governed by the laws of the State of California. Disputes exceeding $5,000 shall be resolved by binding arbitration in Los Angeles County, California, under the rules of the American Arbitration Association. Either party may seek injunctive relief in court if needed.
Signature
WCC Technologies Group
By: _______________________________
Name: Johnny Haygood
Title: President
Date: _______________________________
Client
By: _______________________________
Name: ____________________________
Title: _____________________________
Date: _______________________________
WCC Technologies2nd Authorized Signature:
___________________________________
Signature
___________________________________
Name
___________________________________
Title
___________________________________
Date
Approved as to Form:
__________________________________
Zaynah Moussa-Milward, City Attorney
Attest:
_______________________________
Genoveva Rocha, City Clerk
Brian Saeki
City Administrator