RFB 23-24-34
Network Fiber Connection at Visalia Animal Care Center
38 SAMPLE CONTRACT
NETWORK FIBER CONNECTION AT
VISALIA ANIMAL CARE CENTER
(City of Visalia Bid No. 23-24-34)
This Agreement, entered into and effective this ________ day of ________________, 2024
R E C I T A L S
WHEREAS, CONTRACTOR is an ____________________ (insert individual or entity type) with a primary business address of ____________________ and SSN or EIN: ____________________; and WHEREAS, CITY is a municipal corporation and Charter Law City; and WHEREAS, CITY desires completion of the NETWORK FIBER CONNECTION Project , which was let to bid on ___________ as evidenced by Bid No.23-24-34,
WHEREAS, City of Visalia reviewed and evaluated responses to the Bid and determined to award a contract to CONTRACTOR for the Project; and
WHEREAS, CONTRACTOR represents it is licensed, qualified and willing to complete the Project pursuant to terms and conditions of this Agreement.
NOW, THEREFORE, CITY and CONTRACTOR agree as follows:
1. TERM:
The term of this Agreement shall commence on the Effective Date and expire upon completion of all obligations of the parties, unless earlier terminated by the parties. The indemnification and defense provisions shall survive expiration and termination. Suspension or termination of this Agreement may occur if CONTRACTOR materially fails to comply with any term of the award. Additionally, this Agreement may be terminated for convenience. In the event of termination or expiration of this Agreement, CONTRACTOR shall transfer to CITY any funds and/or accounts receivable on hand attributable to the use of CITY funds.
2. ATTACHMENTS INCORPORATED:
The following are attachments for this Agreement. Said attachments are incorporated into this Agreement as if included in full in the body:
ATTACHMENT NO. DESCRIPTION OF ATTACHMENT
Attachment 1 Contract General Provisions
Attachment 2 Insurance Requirements
Attachment 3 City of Visalia Bid 23-24-34 Network Fiber Connection at Visalia Animal Care Center
Attachment 4 bid in response to Bid No. 23-24-34
3. CONTRACTOR SCOPE OF SERVICES:
County Line Resources
8/14/24
Corporation
1077 N Willow Ave Ste 105
Clovis, CA 93611
82-5314870
RFB 23-24-34
Network Fiber Connection at Visalia Animal Care Center
39 CONTRACTOR shall provide all services/products as requested in Bid No. 23-24-34 for the stated compensation on or before the stated completion dates.
4. CITY COMMITMENTS:
CITY shall perform the following tasks on or before the stated completion dates:
TASK COMPLETION DATE
Pay Contractor as work is completed and invoiced Within 30 days of receipt of approved invoice.
5. COMPENSATION:
CITY shall pay CONTRACTOR compensation for services as indicated in Paragraph 4 above; however, CITY shall pay no more than the following amount as total compensation under this Agreement, unless otherwise agreed in writing. Such sum shall be expended and paid by CITY on a reimbursement basis for services actually performed based on invoices, receipts, time sheets and similar documents presented by CONTRACTOR to CITY.
*CONTRACTOR may elect to avoid the 5% retention by depositing securities of equivalent value pursuant to California Public Contract Code Section 22300.
IN WITNESS WHEREOF, this Agreement is executed on the day and year first above written.
CONTRACTOR
Dated: ___________________ By:______________________________________________________ Authorized Officer: I certify under penalty of perjury under the laws of the State of California that I am fully authorized to execute this Agreement for CONTRACTOR in the capacity I have stated, and that such execution is sufficient to bind the CONTRACTOR.
CITY OF VISALIA
Dated: ____________________ By:______________________________________________________ City Manager
Dated: ____________________ By:______________________________________________________ City Attorney
Dated: ____________________ By:______________________________________________________ City of Visalia Risk Manager
Dated: ____________________ By:______________________________________________________ City of Visalia Project Manager
Total Compensation: $
Payment Schedule: Within 45 days from receipt of approved invoice for completed work, less 5% retention until 35 days after work is completed and accepted by CITY as evidenced by the recordation of a Notice of Completion*
$145,500.00
RFB 23-24-34
Network Fiber Connection at Visalia Animal Care Center
40 Attachment 1 - CONTRACT GENERAL PROVISIONS
A. Successors and Assigns: This Agreement shall be binding upon and shall inure to the benefit of any successors to or assigns of the parties.
B. Prohibition of Assignment : Neither party shall assign, delegate or transfer their rights and duties in this Agreement without the written consent of the other party.
C. Notices : Notice shall be sufficient hereunder if personally served upon the City Clerk of the CITY or an officer or principal of the CONTRACTOR, or if sent via the United States Postal Service, postage prepaid, addressed as follows:
CITY OF VISALIA CONTRACTOR
707 W. Acequia Ave. _______________________
Visalia, CA 93291 _______________________
Attention: City Clerk Attention: _____________
D. Independent Contractor: It is understood and agreed by the parties herein that CONTRACTOR, in the performance of this Agreement, shall act as an independent contractor, and therefore shall obtain no rights to any fringe benefits that accrue to regular full-time CITY employees.
E. Jurisdiction/Venue/Waiver Of Removal : This Agreement shall be administered and interpreted under the laws of the State of California. Jurisdiction of litigation arising from this Agreement shall be in California. Any action brought to interpret or enforce this Agreement, or any of the terms or conditions hereof, shall be brought in Tulare County, California. The CONTRACTOR hereby expressly waives any right to remove any action to a county other than Tulare County as permitted pursuant to Section 394 of the California Code of Civil Procedure.
F. Integration/Modification: This Agreement and each of the documents and exhibits or attachments referenced herein, which are incorporated by reference, represents the entire understanding of the parties as to those matters contained herein. No prior oral or written understanding shall be of any force or effect with respect to those matters covered hereunder.
This Agreement may not be modified or altered except in writing signed by the parties, unless otherwise explicitly authorized.
G. Conflict With Law : If any part of this Agreement is found to be in conflict with applicable laws, such part shall be inoperative, null and void insofar as it is in conflict with said law, but the remainder of the Agreement shall be in full force and effect.
H. Indemnification : The CONTRACTOR waives any and all claims and recourse against the CITY, including the right of contribution of loss or damage to person or property arising from, growing Agreement, except claims arising from the concurrent or sole negligence of the CITY or its officers, agents or employees. The CONTRACTOR will indemnify, hold harmless, and defend (at arising out of the concurrent or sole negligence of the CITY or its officers, agents, or employees.
I. Guarantees and Warranties:
1. IN GENERAL: All guarantees and warranties specifically called for by the specifications and/or this Agreement shall expressly run to the benefit of the CITY.
2. ONE YEAR GUARANTEE: Besides guarantees required elsewhere, CONTRACTOR shall and hereby does guarantee the project work for a period of one year after the date of acceptance by CITY.
RFB 23-24-34
Network Fiber Connection at Visalia Animal Care Center
41 3. WARRANTIES: Warranties required by the Invitation to Bid or this Agreement shall commence on the date of acceptance of the work by CITY, unless otherwise provided in a Certificate of Substantial Completion.
CONTRACTOR warrants that the materials and equipment furnished under the Agreement will be new and of recent manufacturer unless otherwise specified, and that all work will be of good quality, free from faults and defects, and in conformance with the Agreement. Work that does not conform may be considered defective. This warranty excludes remedy for damage or defect caused by abuse, modifications not executed by the CONTRACTOR, improper or insufficient maintenance, improper operation, or normal wear and tear under normal usage.
CONTRACTOR warrants that title to all work covered by an application for payment will pass to the CITY either by incorporation in the construction or upon the receipt of payment by the CONTRACTOR, whichever occurs first, free and clear of all liens.
CONTRACTOR warrants and guarantees that title to all work, materials, and equipment covered by any application for payment, whether incorporated in the project or not, will pass to CITY no later than the time of payment free and clear of all liens.
No materials or supplies for the project shall be purchased by the CONTRACTOR or SUBCONTRACTOR subject to any mortgage or under a condition of sale contract or other agreement by which an interest is retained by the seller. CONTRACTOR warrants that it has good title to all materials and supplies used by it in the project, free from all liens.
CONTRACTOR shall indemnify and hold CITY harmless from all claims growing out of the lawful demands of SUBCONTRACTORS, laborers, workers, mechanics, material persons, and furnishers of machinery and parts thereof, equipment, power tools, and all supplies, incurred in furnish satisfactory evidence that all obligations of the nature here and above designated have been paid, discharged, or waived. If CONTRACTOR fails to do so, then CITY may, after having served written notice on the CONTRACTOR, either pay directly unpaid bills, of which the CITY deemed reasonably sufficient to pay any and all such lawful claims until satisfactory evidence is furnished that all liabilities have been fully discharged where upon payment to the CONTRACTOR shall be resumed, in accordance of the terms of this Agreement, but in no event shall the provisions of this sentence be construed to impose any obligations on the CITY to either the CONTRACTOR or its surety. In paying any unpaid bills of the CONTRACTOR, the CITY shall be deemed the agent of the CONTRACTOR and any payment so made by the CITY shall be considered as payment made under the contract by the CITY to the CONTRACTOR and the CITY shall not be liable to the CONTRACTOR for any such payments made in good faith.
Any defective work that is either corrected or replaced shall be warrantied and guaranteed for a period of one year from the date of such correction or replacement.
J. : In the event either party commences any action, arbitration or legal proceedings for the enforcement of this Agreement, the prevailing party, as determined by the the action brought thereon.
K. Headings : Section headings are provided for organizational purposes only and do not in any manner affect the scope or intent of the provisions thereunder.
L. Firearms Prohibited: Guns may not be carried by contractors /vendors/consultants while working on City of Visalia premises without the expressed written approval of a City of Visalia RFB 23-24-34
Network Fiber Connection at Visalia Animal Care Center
42 Department Head, or an exemption in the contract. If a contractor/vendor/ consultant is caught carrying a gun, without City permission, their contract will be terminated.
M. Executive Order N-6-22 Russia Sanctions
On March 4, 2022, Governor Gavin Newsom issued Executive Order N-6-22 (the EO) regarding as well as any sanctions imposed under state law. The EO directs state agencies to terminate contracts with, and to refrain from entering any new contracts with, individuals or entities that are determined to be a target of Economic Sanctions. Accordingly, should the State determine Contractor is a target of Economic Sanctions or is conducting prohibited transactions with sanctioned individuals or entities, that shall be grounds for termination of this agreement. The State shall provide Contractor advance written notice of such termination, allowing Contractor at least 30 calendar days to provide a written response. Termination shall be at the sole discretion of the State.
N. Time is of the Essence : Time is of the essence in the performance of the construction anticipated by this Contract.
O. Liquidated Damages : City and contractor acknowledge and agree that time is of the essence for this project. Therefore, for each day the project is delayed beyond the agreed completion date of thirty (30) calendar days, it would be extremely difficult and impractical to ascertain the extent of the detriment to city. The parties have determined and agreed that the actual amount of damages that would be suffered by city as a result of any such delay is the sum of two hundred dollars ($200.00) per day, which is a reasonable estimate of the amount of such damages. The payment of such amount as liquidated damages is not intended as a forfeiture or penalty within the meaning of California civil code sections 3275 or 3369, but is intended to constitute liquidated damages to city pursuant to California civil code sections 1671, 1676 and 1677. City hereby waives the provisions of California civil code section 3389. City agrees that these liquidated damages shall be in lieu of any other monetary relief or other remedy for delay, including, without limitation, specific performance, to which city might otherwise be entitled under this agreement, at law or in equity, agreement.
RFB 23-24-34
Network Fiber Connection at Visalia Animal Care Center
43 Attachment 2 - CONTRACT INSURANCE REQUIREMENTS
1. CONTRACTOR Insurance. CONTRACTOR, at its sole cost and expense, for the full term of this Agreement (and any extensions thereof), shall obtain and maintain at a minimum compliance with all of the following insurance coverage(s) and requirements. Such insurance coverage shall be primary coverage as respects CITY and any insurance or self-insurance maintained by CITY shall be in excess
2. . If CONTRACTOR utilizes one or more subcontractors in the performance of this Agreement, CONTRACTOR shall obtain and maintain independent insurance as to each subcontractor or otherwise provide evidence of insurance coverage for each subcontractor equivalent to that required of CONTRACTOR in this Agreement.
3. Types of Insurance and Minimum Limits. The following types of insurance and minimum limits are required providing at least the following minimum coverage and limits of liability:
a.
coverage for any and all employees of CONTRACTOR in the minimum statutorily required coverage amounts;
b.
this Agreement, including owned, non-
contractors), leased or hired vehicles, in the minimum amount of $1,000,000 combined single limit per occurrence for bodily injury and property damage. This insurance coverage shall not be required if vehicle used by CONTRACTOR is not a material part of performance of this Agreement.
c. Comprehensive or Commercial General Liability Insurance coverage in the minimum amount of $1,000,000 combined single limit, including coverage for:
(1) bodily injury;
(2) personal injury;
(3) broad form property damage;
(4) contractual liability;
(5) cross-liability;
(6) products and completed operations liability
4. Other Insurance Provisions.
extensions thereof. CONTRACTOR may maintain the required post agreement coverage by renewal or purchase of prior acts or tail coverage. This provision is contingent upon post agreement coverage being both available and reasonably affordable in relation to the coverage provided during the term of this Agreement. For purposes of interpreting this requirement, a cost not exceeding 100% of the last annual policy premium during the term of this Agreement in order to purchase prior acts or tail coverage for post agreement coverage shall be deemed to be reasonable.
5. Endorsements.
All required Automobile and Comprehensive or Commercial General Liability Insurance shall be endorsed to contain the following clauses:
a. The City of Visalia, its officers, agents, employees, representatives, and volunteers are added as additional insureds as respects operations and activities of, or on behalf of the named insured, performed under contract with the City of Visalia.
RFB 23-24-34
Network Fiber Connection at Visalia Animal Care Center
44 b. It is agreed that any insurance maintained by the City of Visalia shall apply in excess of and not contribute with insurance provided by this policy.
c. This insurance shall not be canceled, limited in scope or coverage, or non-renewed until after thirty (30) days prior written notice has been given to the City Clerk, City of Visalia, 707 W.
Acequia, Visalia, CA, 93291
6. Proof of Coverage.
CONTRACTOR agrees to provide its insurance broker(s) with a full copy of these insurance provisions and provide CITY on or before the effective date of this Agreement with Certificate(s) of Insurance for all required coverages. Copies of all the required Endorsements shall be attached to the Certificate(s) of Insurance or other evidence of insurance acceptable to the City of Visalia, coverages. This Proof of Coverage shall then be mailed to the City of Visalia at the following address:
City of Visalia
707 W. Acequia
Visalia, CA 93291
Attn: Purchasing Division
RFB 23-24-34
Network Fiber Connection at Visalia Animal Care Center
45 Awarded Contractor shall complete and submit this form with final payment request.
SAMPLE FINAL PAYMENT AFFIDAVIT
I, declare under penalty of perjury
Name)
under the laws of the State of California and the provisions of the California Labor Code §1771, §1773.1, §1775, §1776, §1777.5, §1813 and §1815 that:
1. I am the of and I
(Officer, Owner, Partner) (Company)
am responsible for the payment of persons employed by
(Company)
who performed work on the City of Visalia Project entitled:
ANIMAL CARE CENTER FIBER NETWORK CONNECTION
2. During all payroll periods from through ,
(first work date) (last work date)
All persons employed by on this project
(Company)
have at all times been paid, at a minimum, the specified general prevailing rate of per diem wages and any amounts due.
3. During all payroll periods on this project, all apprenticeship requirements have been complied with.
Executed and sworn to this day of ,
(Day) (Month) (Year)
___________________________________ __________________ (Signature) (Date)