Proper system startup will require:
• Adequate moisture control (target ~40–60% media moisture) • Humidified inlet air conditions
• Sufficient H S loading to sustain microbial activity
885
Scope of Supply - The following items shall be supplied in accordance with RFB No. 25-26-16:
A. Fiber-Max™ biofilter media – 24,750 ft³ (916 yd³) for Cells A and B
1. Base 3’-0” media depth
2. Additional 9” of media for settling of media bed
3. Total bed depth is 3’-9”
B. Freight – approximately ten (10) roll-off double trailer loads to project site C. Biofilter smoke testing (final distribution verification) with report D. Media irrigation coverage inspection
E. Required submittals and media sample
Proposed Fiber-Max™ Media:
The above quoted price includes no sales tax.
The above prices are firm for a period of 30 days from the date of this proposal.
EXCLUSION: Items not specifically quoted above are EXCLUDED.
FREIGHT: Delivered to project site, freight included
DELIVERY: Delivered to project site; shipments scheduled to align with plant operations Payment Terms:
All orders are submitted and subject to our Credit Services Department review and approval. NO RETAINER ALLOWANCE unless otherwise negotiated. Payment terms shall be:
• 25% deposit with purchase order
• NET 30 days each invoice
Delivery Schedule:
The media delivery will be scheduled for 5-6 weeks after the notice to proceed is received.
Truckload deliveries shall be scheduled to assist with the plant unloading schedule.
Items to be provided “By Others”:
The following shall be by others for the above:
• Unloading, and installation of the supplied media
• BacTee Floor replacements
• Liner replacement or modifications\
• TenDrain screen
• Demolition requirements
• Temporary odor control system and controls
• Spray nozzles, Interconnecting PVC piping and valves
• Adjusting and Air Balancing of the Equipment with Report Description Total
24,750ft³ of Fiber-Max™ Media and Smoke Test $
Freight to Visalia, CA 93277 – Ten (10) Roll Off Doubles $ Total $
886
GES Biotek is confident that the proposed Fiber-Max™ media provides a reliable, engineered approach to biofiltration with improved consistency, biological performance, and reduced operational risk compared to conventional compost-based media. We appreciate your consideration and look forward to supporting this project.
Regards,
Steve McCance
Steve McCance
Vice President of Operations
GES Biotek, LLC
Office Phone: (630) 473-3874
Cell Phone: (909) 677-1019 (Preferred)
E-Mail: [email protected]
Website: www.gesbiotek.com
Visalia Water Reclamation Plant Project 6.24.2026 Proposal #4544 Encl: GES Terms and Conditions of Sale
Fiber-Max™ Sales Sheet
887
Biofilter Media Replacement & Associated Equipment Inspection
PROJECT AGREEMENT
BIOFILTER MEDIA REPLACEMENT & ASSOCIATED EQUIPMENT INSPECTION AT THE
WATER RECLAMATION FACILITY
This Agreement, entered into and effective this ________ day of ________________, 2026 [“Effective Date”], by and between the City of Visalia, hereinafter referred to as the “CITY”, and ____________________________ hereinafter referred to as the “CONTRACTOR”, “BIDDER”, or “SUBRECIPIENT”.
R E C I T A L S
WHEREAS, CONTRACTOR is an ____________________ (insert individual or entity type) with a primary business address of ____________________ and SSN or EIN: ____________________; and WHEREAS, CITY is a municipal corporation and Charter Law City; and WHEREAS, CITY desires completion of the Biofilter Media Replacement & Associated Equipment Inspection Project, previously defined in RFB 25-26-16 for scope reference only and subsequently procured through the City’s informal quote process; and WHEREAS, City of Visalia reviewed and evaluated responses to the Bid and determined to award a contract to CONTRACTOR for the Project; and
WHEREAS, CONTRACTOR represents it is licensed, qualified and willing to complete the Project pursuant to terms and conditions of this Agreement.
NOW, THEREFORE, CITY and CONTRACTOR agree as follows:
1. TERM:
The term of this Agreement shall commence on the Effective Date and expire upon completion of all obligations of the parties, unless earlier terminated by the parties. The indemnification and defense provisions shall survive expiration and termination. Suspension or termination of this Agreement may occur if CONTRACTOR materially fails to comply with any term of the award. Additionally, this Agreement may be terminated for convenience. In the event of termination or expiration of this Agreement, CONTRACTOR shall transfer to CITY any funds and/or accounts receivable on hand attributable to the use of CITY funds.
2. ATTACHMENTS INCORPORATED:
The following are attachments for this Agreement. Said attachments are incorporated into this Agreement as if included in full in the body:
ATTACHMENT NO. DESCRIPTION OF ATTACHMENT
Attachment 1 General Contract Provisions
Attachment 2 Insurance Requirements
Attachment 3 Certificates, Guarantees, and Affidavits for the Biofilter Media Replacement & Associated Equipment Inspection Project
Attachment 4 CONTRACTOR’s informal quote for this Project (including RFB 25-26-16 for scope reference only)
3. CONTRACTOR SCOPE OF SERVICES and COMMITMENTS*:
CONTRACTOR shall provide the following services for the stated compensation on or before the stated completion dates (“Scope of Services”):
888
Biofilter Media Replacement & Associated Equipment Inspection All work described in the Scope of Services as defined in the informal quote submitted by CONTRACTOR, incorporating the technical specifications and scope requirements originally set forth in RFB 25-26-16 for reference. (RFB 25-26-16 was used solely to define scope and technical requirements; the Project was procured via an informal quote process.)
4. CITY COMMITMENTS:
CITY shall perform the following tasks on or before the stated completion dates:
TASK COMPLETION DATE
Pay Contractor as work is completed and invoiced As requested by Contractor
5. COMPENSATION:
CITY shall pay CONTRACTOR compensation for services as indicated in Paragraph 4 above; however, CITY shall pay not more than the following amount as total compensation under this Agreement, unless otherwise agreed in writing. Such sum shall be expended and paid by CITY on a reimbursement basis for services actually performed based on invoices, receipts, time sheets and similar documents presented by CONTRACTOR to CITY. *CONTRACTOR may elect to avoid the 5% retention by depositing securities of equivalent value pursuant to California Public Contract Code Section 22300.
IN WITNESS WHEREOF, this Agreement is executed on the day and year first above written.
CONTRACTOR
Dated: ___________________ By:______________________________________________________ Authorized Officer: I certify under penalty of perjury under the laws of the State of California that I am fully authorized to execute this Agreement for CONTRACTOR in the capacity I have stated, and that such execution is sufficient to bind the CONTRACTOR.
CITY OF VISALIA
Dated: ____________________ By:______________________________________________________ City Manager
Dated: ____________________ By:______________________________________________________ City Attorney
Dated: ____________________ By:______________________________________________________ City of Visalia Risk Manager
Dated: ____________________ By:______________________________________________________ City of Visalia Project Manager
Total Compensation: $
Source of Funds: Local Revenues
Payment Schedule: Within 30 days from receipt of approved invoice for completed work, less 5% retention until 35 days after work is completed and accepted by CITY as evidenced by the recordation of a Notice of Completion*
889
Biofilter Media Replacement & Associated Equipment Inspection Attachment 1
GENERAL CONTRACT PROVISIONS
A. Successors and Assigns: This Agreement shall be binding upon and shall inure to the benefit of any successors to or assigns of the parties.
B. Prohibition of Assignment: Neither party shall assign, delegate or transfer their rights and duties in this Agreement without the written consent of the other party.
C. Notices: Notice shall be sufficient hereunder if personally served upon the City Clerk of the CITY or an officer or principal of the CONTRACTOR, or if sent via the United States Postal Service, postage prepaid, addressed as follows:
CITY OF VISALIA CONTRACTOR
707 W. Acequia Ave. _______________________
Visalia, CA 93291 _______________________
Attention: City Clerk Attention: _____________
D. Independent Contractor: It is understood and agreed by the parties herein that CONTRACTOR, in the performance of this Agreement, shall act as an independent contractor, and therefore shall obtain no rights to any fringe benefits that accrue to regular full-time CITY employees.
E. Jurisdiction/Venue/Waiver Of Removal: This Agreement shall be administered and interpreted under the laws of the State of California. Jurisdiction of litigation arising from this Agreement shall be in California. Any action brought to interpret or enforce this Agreement, or any of the terms or conditions hereof, shall be brought in Tulare County, California. The CONTRACTOR hereby expressly waives any right to remove any action to a county other than Tulare County as permitted pursuant to Section 394 of the California Code of Civil Procedure.
F. Integration/Modification: This Agreement and each of the documents and exhibits or attachments referenced herein, which are incorporated by reference, represents the entire understanding of the parties as to those matters contained herein. No prior oral or written understanding shall be of any force or effect with respect to those matters covered hereunder. This Agreement may not be modified or altered except in writing signed by the parties, unless otherwise explicitly authorized.
G. Conflict With Law: If any part of this Agreement is found to be in conflict with applicable laws, such part shall be inoperative, null and void insofar as it is in conflict with said law, but the remainder of the Agreement shall be in full force and effect.
H. Indemnification: The CONTRACTOR waives any and all claims and recourse against the CITY, including the right of contribution of loss or damage to person or property arising from, growing out of, or in any way connected with or incidental to the CONTRACTOR’s performance of this Agreement, except claims arising from the concurrent or sole negligence of the CITY or its officers, agents or employees. The CONTRACTOR will indemnify, hold harmless, and defend (at CITY’s option) the CITY against any and all claims, demands, damages, costs, expenses, or liability arising out of the CONTRACTOR’s performance of this Agreement except for liability arising out of the concurrent or sole negligence of the CITY or its officers, agents, or employees.
I. Guarantees and Warranties:
1. IN GENERAL: All guarantees and warranties specifically called for by the specifications and/or this Agreement shall expressly run to the benefit of the CITY.
2. ONE YEAR GUARANTEE: Besides guarantees required elsewhere, CONTRACTOR shall and hereby does guarantee the project work for a period of one year after the date of acceptance by CITY.
890
Biofilter Media Replacement & Associated Equipment Inspection
3. WARRANTIES: Warranties required by the Invitation to Bid or this Agreement shall commence on the date of acceptance of the work by CITY, unless otherwise provided in a Certificate of Substantial Completion.
CONTRACTOR warrants that the materials and equipment furnished under the Agreement will be new and of recent manufacturer unless otherwise specified, and that all work will be of good quality, free from faults and defects, and in conformance with the Agreement. Work that does not conform may be considered defective. This warranty excludes remedy for damage or defect caused by abuse, modifications not executed by the CONTRACTOR, improper or insufficient maintenance, improper operation, or normal wear and tear under normal usage.
CONTRACTOR warrants that title to all work covered by an application for payment will pass to the CITY either by incorporation in the construction or upon the receipt of payment by the CONTRACTOR, whichever occurs first, free and clear of all liens.
CONTRACTOR warrants and guarantees that title to all work, materials, and equipment covered by any application for payment, whether incorporated in the project or not, will pass to CITY no later than the time of payment free and clear of all liens.
No materials or supplies for the project shall be purchased by the CONTRACTOR or SUBCONTRACTOR subject to any mortgage or under a condition of sale contract or other agreement by which an interest is retained by the seller. CONTRACTOR warrants that it has good title to all materials and supplies used by it in the project, free from all liens.
CONTRACTOR shall indemnify and hold CITY harmless from all claims growing out of the lawful demands of SUBCONTRACTORS, laborers, workers, mechanics, material persons, and furnishers of machinery and parts thereof, equipment, power tools, and all supplies, incurred in furtherance of the performance of this Agreement. CONTRACTOR shall, at CITY’s request, furnish satisfactory evidence that all obligations of the nature here and above designated have been paid, discharged, or waived. If CONTRACTOR fails to do so, then CITY may, after having served written notice on the CONTRACTOR, either pay directly unpaid bills, of which the CITY has written notice, or withhold from the CONTRACTOR’s unpaid compensation a sum of money deemed reasonably sufficient to pay any and all such lawful claims until satisfactory evidence is furnished that all liabilities have been fully discharged where upon payment to the CONTRACTOR shall be resumed, in accordance of the terms of this Agreement, but in no event shall the provisions of this sentence be construed to impose any obligations on the CITY to either the CONTRACTOR or its surety. In paying any unpaid bills of the CONTRACTOR, the CITY shall be deemed the agent of the CONTRACTOR and any payment so made by the CITY shall be considered as payment made under the contract by the CITY to the CONTRACTOR and the CITY shall not be liable to the CONTRACTOR for any such payments made in good faith.
Any defective work that is either corrected or replaced shall be warrantied and guaranteed for a period of one year from the date of such correction or replacement.
J. Attorney’s Fees: In the event either party commences any action, arbitration or legal proceedings for the enforcement of this Agreement, the prevailing party, as determined by the court or arbitrator, shall be entitled to recovery of its attorney’s fees and court costs incurred in the action brought thereon.
K. Headings: Section headings are provided for organizational purposes only and do not in any manner affect the scope or intent of the provisions thereunder.
L. Firearms Prohibited: Guns may not be carried by contractors /vendors/consultants while working on City of Visalia premises without the expressed written approval of a City of Visalia Department Head, or an exemption in the contract. If a 891
Biofilter Media Replacement & Associated Equipment Inspection contractor/vendor/ consultant is caught carrying a gun, without City permission, their contract will be terminated.
M. Executive Order N-6-22 – Russia Sanctions
On March 4, 2022, Governor Gavin Newsom issued Executive Order N-6-22 (the EO) regarding Economic Sanctions against Russia and Russian entities and individuals. “Economic Sanctions” refers to sanctions imposed by the U.S. government in response to Russia’s actions in Ukraine, as well as any sanctions imposed under state law. The EO directs state agencies to terminate contracts with, and to refrain from entering any new contracts with, individuals or entities that are determined to be a target of Economic Sanctions. Accordingly, should the State determine Contractor is a target of Economic Sanctions or is conducting prohibited transactions with sanctioned individuals or entities, that shall be grounds for termination of this agreement. The State shall provide Contractor advance written notice of such termination, allowing Contractor at least 30 calendar days to provide a written response. Termination shall be at the sole discretion of the State.
N. Time is of the Essence: Time is of the essence in the performance of the construction anticipated by this Contract.
O. Liquidated Damages: CITY AND CONTRACTOR ACKNOWLEDGE AND AGREE THAT TIME IS OF THE ESSENCE FOR THIS PROJECT. THEREFORE, FOR EACH DAY THE
PROJECT IS DELAYED BEYOND THE AGREED COMPLETION DATE OF ONE HUNDRED TWENTY (120) CALENDAR DAYS, IT WOULD BE EXTREMELY DIFFICULT AND IMPRACTICAL TO ASCERTAIN THE EXTENT OF THE DETRIMENT TO CITY. THE PARTIES
HAVE DETERMINED AND AGREED THAT THE ACTUAL AMOUNT OF DAMAGES THAT
WOULD BE SUFFERED BY CITY AS A RESULT OF ANY SUCH DELAY IS THE SUM OF SEVEN HUNDRED FIFTY DOLLARS ($750.00) PER DAY, WHICH IS A REASONABLE ESTIMATE OF THE AMOUNT OF SUCH DAMAGES. THE PAYMENT OF SUCH AMOUNT
AS LIQUIDATED DAMAGES IS NOT INTENDED AS A FORFEITURE OR PENALTY WITHIN THE MEANING OF CALIFORNIA CIVIL CODE SECTIONS 3275 OR 3369, BUT IS
INTENDED TO CONSTITUTE LIQUIDATED DAMAGES TO CITY PURSUANT TO CALIFORNIA CIVIL CODE SECTIONS 1671, 1676 AND 1677. CITY HEREBY WAIVES THE PROVISIONS OF CALIFORNIA CIVIL CODE SECTION 3389. CITY AGREES THAT THESE
LIQUIDATED DAMAGES SHALL BE IN LIEU OF ANY OTHER MONETARY RELIEF OR
OTHER REMEDY FOR DELAY, INCLUDING, WITHOUT LIMITATION, SPECIFIC
PERFORMANCE, TO WHICH CITY MIGHT OTHERWISE BE ENTITLED UNDER THIS AGREEMENT, AT LAW OR IN EQUITY, AND SHALL BE CITY’s SOLE AND EXCLUSIVE RIGHT AND REMEDY, EXCEPT THAT CITY MAY TERMINATE THE AGREEMENT.
CITY CONTRACTOR ________
892
Biofilter Media Replacement & Associated Equipment Inspection Attachment 2
INSURANCE REQUIREMENTS
1. CONTRACTOR Insurance. CONTRACTOR, at its sole cost and expense, for the full term of this Agreement (and any extensions thereof), shall obtain and maintain at a minimum compliance with all of the following insurance coverage(s) and requirements. Such insurance coverage shall be primary coverage as respects CITY and any insurance or self-insurance maintained by CITY shall be in excess of CONTRACTOR’s insurance coverage and shall not contribute to it.
2. Subcontractor(s’) Insurance. If CONTRACTOR utilizes one or more subcontractors in the performance of this Agreement, CONTRACTOR shall obtain and maintain independent insurance as to each subcontractor or otherwise provide evidence of insurance coverage for each subcontractor equivalent to that required of CONTRACTOR in this Agreement.
3. Types of Insurance and Minimum Limits. The following types of insurance and minimum limits are required providing at least the following minimum coverage and limits of liability:
a. Worker’s Compensation written in accordance with the laws of the State of California providing coverage for any and all employees of CONTRACTOR in the minimum statutorily required coverage amounts;
b. Automobile Liability Insurance for each of CONTRACTOR’s vehicles used in the performance of this Agreement, including owned, non-owned (e.g. owned by CONTRACTOR’s employees or contractors), leased or hired vehicles, in the minimum amount of $1,000,000 combined single limit per occurrence for bodily injury and property damage.
c. Professional Liability insurance coverage, in an amount not less than One Million Dollars ($1,000,000).
d. Comprehensive or Commercial General Liability Insurance coverage in the minimum amount of $1,000,000 combined single limit, including coverage for:
(1) bodily injury;
(2) personal injury;
(3) broad form property damage;
(4) contractual liability;
(5) cross-liability;
(6) products and completed operations liability
4. Other Insurance Provisions.
If any insurance coverage required in this Agreement is provided on a “Claims Made” rather than “Occurrence” form, CONTRACTOR agrees to maintain the required coverage for a period of three (3) years after the expiration of this Agreement (hereinafter “post agreement coverage”) and any extensions thereof. CONTRACTOR may maintain the required post agreement coverage by renewal or purchase of prior acts or tail coverage.
This provision is contingent upon post agreement coverage being both available and reasonably affordable in relation to the coverage provided during the term of this Agreement. For purposes of interpreting this requirement, a cost not exceeding 100% of the last annual policy premium during the term of this Agreement in order to purchase prior acts or tail coverage for post agreement coverage shall be deemed to be reasonable.
5. Endorsements.
All required Automobile and Comprehensive or Commercial General Liability Insurance shall be endorsed to contain the following clauses:
a. The City of Visalia, its officers, agents, employees, representatives, and volunteers are added as additional insureds as respects operations and activities of, or on behalf of the named insured, performed under contract with the City of Visalia. 893
Biofilter Media Replacement & Associated Equipment Inspection b. It is agreed that any insurance maintained by the City of Visalia shall apply in excess of and not contribute with insurance provided by this policy. c. This insurance shall not be canceled, limited in scope or coverage, or non-renewed until after thirty (30) days prior written notice has been given to the City Clerk, City of Visalia, 707 W. Acequia, Visalia, CA, 93291
6. Proof of Coverage.
CONTRACTOR agrees to provide its insurance broker(s) with a full copy of these insurance provisions and provide CITY on or before the effective date of this Agreement with Certificate(s) of Insurance for all required coverages. Copies of all the required Endorsements shall be attached to the Certificate(s) of Insurance or other evidence of insurance acceptable to the City of Visalia, which shall be provided by CONTRACTOR’s insurance company as evidence of the stipulated coverages. This Proof of Coverage shall then be mailed to the City of Visalia at the following address:
City of Visalia
707 W. Acequia
Visalia, CA 93291
Attn: Purchasing Division
894
Biofilter Media Replacement & Associated Equipment Inspection Attachment 3 Certificates, Guarantees and Affidavits
BID GUARANTEE
Known all men by these presents:
That we, ____________________________ ________________ as principal and __________________________________________________ as surety, are held and firmly bound unto the City of Visalia (obligee) in the sum of ten percent (10%) of the total amount of the bid of the principal, to be paid to the said City or its certain attorney, its successors and assigns, for which payment well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors or assigns, jointly and severally, firmly by these presented.
In no case shall the liability of the surety hereunder exceed the sum of $____________________.
THE CONDITION OF THIS OBLIGATION IS SUCH, that whereas the principal has submitted the above mentioned bid to the City of Visalia for certain construction specifically described as follows, for which bids are to be opened at ___________________________ on ___________________________________ for improvement of Project: Biofilter Media Replacement & Associated Equipment Inspection at Visalia Water Reclamation Facility
NOW THEREFORE, if the aforesaid principal is awarded the contract, and within the time and manner required under the specifications, after the prescribed form in accordance with the bid, and files the two bonds with the City of Visalia, one to guarantee faithful performance and the other to guarantee payment of labor and materials, as required by law, then this obligation shall be null and void, otherwise it shall be and remain in full force and effect.
In the event suit is brought upon this bond by the obligee and judgment is recovered, the surety shall pay all costs incurred by the obligee in such suit, including a reasonable attorney’s fee to be fixed by the court.
IN WITNESS WHEREOF, we have hereunto set our hands and seals on this _______________________________ day of _______________________________, 2026
Company (Principal): ______________________________________________ Business Address: ______________________________________________ Signature:_______________________________________________________________ ___ Date:________________________ Name of Signing Official: _____________________________________________________ Title:_________________________ Company Seal (if any):
Company (Surety): ______________________________________________ Business Address: ______________________________________________ Signature:_______________________________________________________________ ___ Date:________________________ Name of Signing Official: _____________________________________________________ Title:_________________________
Company Seal (if any):
Note: Signatures of those executing for the surety must be properly acknowledged. 895
Biofilter Media Replacement & Associated Equipment Inspection
NON-COLLUSION AFFIDAVIT
(Title 23 United States Code Section 112 and Public Contract Code Section 7106) In accordance with Title 23 United States Code section 112 and Public Contract Code 7106 the bidder declares that bid is not made in the interest of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price of the bidder or any other bidder, or to fix any overhead, profit, or cost element of the bid price, or of that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay, any fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. __________________________________________ ________________________ Signature Date
Note: The above Non-collusion Affidavit is part of the Bid/Proposal.
Bidders are cautioned that making a false certification may subject the certifier to criminal prosecution.
896
Biofilter Media Replacement & Associated Equipment Inspection WORKERS’ COMPENSATION INSURANCE CERTIFICATE
(CALIF. LABOR CODE § 3700)
STATE OF CALIFORNIA )
) ss
CITY OF VISALIA )
I am aware of the provisions of Section 3700 of the Labor Code which requires every employer to be insured against liability for workers’ compensation or to undertake self-insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work under this contract.
Company: ______________________________________________ Business Address: ______________________________________________ Signature: ______________________________________________ Name of Signing Official: ______________________________________________ Title of Signing Official: ______________________________________________ Date: ______________________________________________
Company Seal (if any):
897
Biofilter Media Replacement & Associated Equipment Inspection
EQUAL EMPLOYMENT OPPORTUNITY COMPLIANCE CERTIFICATE
(EXECUTIVE ORDER 11246)
Equal Opportunity Clause
Unless exempted by rules, regulations or orders of the Secretary of Labor issued pursuant to Executive Orders 10925, 11114 or Section 204 of Executive Order 11246 of September 24, 1965, during the performance of each contract with the City of Visalia, the BIDDER agrees as follows:
1. The BIDDER will not discriminate against any employee or applicant for employment because of race, color, religion, gender, national origin or political affiliation. The BIDDER will take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, gender, national origin or political affiliation. Such action shall include, but not be limited to, the following:
employment upgrading, demotion or transfer, recruitment or recruitment advertising, layoff or termination, rates of pay or other forms of compensation, and selection for training, including apprenticeship. The BIDDER agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the contracting officer setting forth the provisions of this nondiscrimination clause.
2. The BIDDER will, in all solicitations or advertisements for employees, placed by or on behalf of the BIDDER, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, gender, national origin or political affiliation.
3. The BIDDER will send to each labor union or representative of workers with which he has a collective bargaining agreement or other contract or understanding, a notice to be provided by the agency contracting officer, advising the labor union or the workers’ representative of the BIDDER’s commitments under Section 202 of Executive Order 11246 of September 24, 1965, and shall post copies of the notice on conspicuous places available to employees and applicants for employment.
4. The BIDDER will comply with all provisions of Executive Order 11246 of September 24, 1965, and the rules, regulations and relevancy orders of the Secretary of Labor.
5. The BIDDER will furnish all information and reports required by Executive Order 11246 of September 24, 1965, and by the rules, regulations and relevant orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records and accounts by the contracting agency and the Secretary of Labor for purposes of investigation to ascertain compliance with such rules, regulations and orders.
6. In the event of the BIDDER’s non-compliance with the non-discrimination clauses of this subcontract or with any of such rules, regulations or orders, this subcontract may be canceled, terminated or suspended, in whole, or in part and the BIDDER may be declared ineligible for further government contracts in accordance with the procedures authorized in accordance with Executive Order 11246 of September 24, 1965, and such other sanctions may be imposed and remedies invoked as provided in Executive Order 11246 of September 24, 1965, or by rule, regulation or order of the Secretary of Labor, or otherwise provided by law.
7. The BIDDER will include the provisions of Paragraphs (1) through (7) in every subcontract or purchase order unless exempted by rules, regulations or orders of the Secretary of Labor issued pursuant to Section 204 of Executive Order 11246 of September 24, 1965, so that such provisions will be binding upon each SUBBIDDER or vendor. The BIDDER will take such action with respect to any subcontract or purchase order as the contracting agency may direct as a means of enforcing such provisions including sanctions for non-compliance. Provided, however, that in the event the BIDDER becomes involved in, or is threatened with litigation with a SUBBIDDER or vendor as a result of such direction by the contracting agency, the BIDDER may request the United States to enter into such litigation to protect the interest of the United States.
Company: ______________________________________________ Business Address: ______________________________________________ Signature:______________________________________________ Date:________________ Name & Title of Signing Official: ______________________________________________ Company Seal (if any)
Note: Executive Order 11246 has been rescinded effective January 2025. 898
Biofilter Media Replacement & Associated Equipment Inspection
OWNERSHIP DISCLOSURE AND CALIFORNIA LEVINE ACT STATEMENT The following disclosure and statement apply to the Bidder/Proposer/Contractor/Consultant/ Vendor/Supplier or Company:
1. submitting a bid or proposal in response to a solicitation by City of Visalia; or
2. as Awardee of a contract/purchase order which is subject to approval by the Visalia City Council.
OWNERSHIP DISCLOSURE
_________________________________________________________________________________________________________ Name of Bidder/Proposer/Contractor/Consultant/Vendor/Supplier or Company _________________________________________________________________________________________________________ Address
List the names of all principals, partners, and/or trustees. For corporations, provide names of officers, directors and all stockholders owning more than 10% equity interest in corporation:
___________________________________________________________________________________________________________ ___________________________________________________________________________________________________________ ___________________________________________________________________________________________________________
CALIFORNIA LEVINE ACT STATEMENT
California Government Code Section 84308, also know as the “Levine Act,” can prohibit members of the Visalia City Council from participating in any action related to a contract if he or she receives any political contributions totaling more than $500 within the previous twelve (12) months, and for twelve (12) months following the date a final decision concerning the contract has been made, from the person or company awarded the contract. The Levine Act also requires disclosure of such contribution(s) by a party to be awarded a specific contract.
The following website contains a list of current Visalia City Council Members, https://www.visalia.city/government/city_council/default.asp. You are responsible for reviewing the names of Visalia City Council Members prior to making the following disclosure:
1. Have you or your company, or any agent on behalf of you or your company, made any political contributions of more than $500 to a Visalia City Council Member in the twelve (12) months preceding the date of the submission of your proposals or the anticipated date of any City Council action related to this contract?
YES:_____ NO:_____. If yes, please identify the City Council Member(s) and date(s) of contribution in the space below:
Council Member(s) Name Date of Contribution(s)
_____________________________ ___________________________ Answering YES, does not preclude the City of Visalia from awarding a contract to your firm or from taking any subsequent action related to the contract. It does, however, preclude the identified Visalia City Council Member(s) from participating in any actions related to this contract.
NOTICE: The disclosure duty under state law continues for twelve (12) months after the award. If the above information regarding contributions changes during this time after the award, then the awardee is required to update this disclosure form.
_____________________________________________________________________________________________ Print or Type Name of Bidder/Proposer/Contractor/Consultant/Supplier/Vendor/Company
Signature of Company Authorized Individual Print or Type Name of Authorized Individual Date 899
Biofilter Media Replacement & Associated Equipment Inspection
STATE OF CALIFORNIA
DRUG-FREE WORKPLACE CERTIFICATION
STD.21 (REV.12-93)
I, the official named below, hereby swear that I am duly authorized legally to bind the contractor or grant recipient to the certification described below. I am fully aware that this certification, executed on the date below, is made under penalty of perjury under the laws of the State of California.
CONTRACTOR/BIDDER FIRM NAME FEDERAL ID NUMBER
BY(Authorized Signature) DATE EXECUTED
PRINTED NAME OF PERSON SIGNING TELEPHONE NUMBER (Include Area Code) ( )
TITLE
CONTRACTOR/BIDDER FIRM’S MAILING ADDRESS
The contractor or grant recipient named above hereby certifies compliance with Government Code Section 8355 in matters relating to providing a drug-free workplace. The above-named contractor or grant recipient will:
1. Publish a statement notifying employees that unlawful manufacture, distribution, dispensation, possession, or use of a controlled substance is prohibited and specifying actions to be taken against employees for violations, as required by Government Code Section 8355(a).
2. Establish a Drug-Free Awareness Program as required by Government Code Section 8355(b), to inform employees about all of the following:
(a) The dangers of drug abuse in the workplace,
(b) The person’s or organization’s policy of maintaining a drug-free workplace, (c) Any available counseling, rehabilitation and employee assistance programs, and (d) Penalties that may be imposed upon employees for drug abuse violations.
3. Provide as required by Government Code Section 8355©, that every employee who works on the proposed contract or grant:
(a) Will receive a copy of the company’s drug-free workplace policy statement, and (b) Will agree to abide by the terms of the company’s statement as a condition of employment on the contract or grant.
4. At the election of the contractor or grantee, from and after the “Date Executed” and until ____________ (NOT TO EXCEED 36 MONTHS), the state will regard this certificate as valid for all contracts or grants entered into between the contractor or grantee and this state agency without requiring the contractor or grantee to provide a new and individual certificate for each contract or grant. If the contractor or grantee elects to fill in the blank date, than the terms and conditions of this certificate shall have the same force, meaning effect and enforceability as if a certificate were separately, specifically, and individually provided for each contract or grant between the contractor or grantee and this state agency. 900
Biofilter Media Replacement & Associated Equipment Inspection
AMERICANS WITH DISABILITIES ACT COMPLIANCE CERTIFICATE
By submission of a bid, the BIDDER certifies it will comply with the Americans with Disabilities Act, 42 U.S.C., 12101 et. seq., and will maintain compliance throughout the life of this Contract.
By commencing performance of the Contract work, the selected BIDDER certifies to the Americans with Disabilities Act compliance.
Company: ______________________________________________ Business Address: ______________________________________________ Signature: ______________________________________________ Name of Signing Official: ______________________________________________ Title of Signing Official: ______________________________________________ Date: ______________________________________________
Company Seal (if any):
901
Biofilter Media Replacement & Associated Equipment Inspection
IRAN CONTRACTING ACT CERTIFICATION
(Public Contract Code Section 2200 et seq.)
As required by California Public Contract Code Section 2204, the Contractor certifies subject to penalty for perjury that the option checked below relating to the Contractor’s status in regard to the Iran Contracting Act of 2010 (Public Contract Code Section 2200 et seq.) is true and correct:
⃝ The Contractor is not:
(1) Identified on the current list of persons and entities engaged in investment activities in Iran prepared by the California Department of General Services in accordance with subdivision (b) of Public Contract Code Section 2203; or (2) A financial institution that extends, for 45 days or more, credit in the amount of $20,000,000 or more to any other person or entity identified on the current list of persons and entities engaging in investment activities in Iran prepared by the California Department of General Services in accordance with subdivision (b) of Public Contract Code Section 2203, if that person or entity uses or will use the credit to provide goods or services in the energy sector in Iran.
⃝ The City has exempted the Contractor from the requirements of the Iran Contracting Act of 2010 after making a public finding that, absent the exemption, the City will be unable to obtain the goods and/or services to be provided pursuant to the Contract. ⃝ The amount of the Contract payable to the Contractor for the Project does not exceed $1,000,000 over the life of the contract (up to 5 years).
Signature:________________________________ Printed Name:_______________________ Title:____________________________________ Agency Name:_________________________ Date:____________________
Note: In accordance with Public Contract Code Section 2205, false certification of this form shall be reported to the California Attorney General and may result in civil penalties equal to the greater of $250,000 or twice the Contract amount, termination of the Contract and/or eligibility to bid on contracts for three years.
902
Biofilter Media Replacement & Associated Equipment Inspection
CERTIFICATE OF NONSEGREGATED FACILITIES
(BIDDERS/SUBCONTRACTORS)
1. “Segregated facilities,” as used in this provision, means any waiting rooms, work areas, rest rooms and wash rooms, restaurants and other eating areas, time clocks, locker rooms and other storage or dressing areas, parking lots, drinking fountains, recreation or entertainment areas, transportation, and housing facilities provided for employees, that are segregated by explicit directive or are in fact segregated on the basis of race, color, religion, or national origin, because of habit, local custom, or otherwise.
2. By the submission of a bid, the BIDDER certifies that it does not and will not maintain or provide for its employees any segregated facilities at any of its establishments, and that it does not and will not permit its employees to perform their services at any location under its control where segregated facilities are maintained. The BIDDER agrees that a breach of this certification is a violation of the Equal Opportunity clause in the contract.
3. By submission of the bid, the BIDDER further agrees that (except where it has obtained identical certifications from proposed SUBCONTRACTORs for specific time periods) it will:
(a) Obtain identical certifications from proposed SUBCONTRACTORs before the award of subcontracts under which the SUB-BIDDER will be subject to the Equal Opportunity clause;
(b) Retain such certifications in its files; and
(c) Forward this certification and the following notice to the proposed SUBCONTRACTORs:
NOTICE OF PROSPECTIVE SUBCONTRACTORS OF REQUIREMENT
FOR CERTIFICATION OF NONSEGREGATED FACILITIES
A certificate of Nonsegregated Facilities must be submitted before the award of a subcontract under which the SUBCONTRACTOR will be subject to the equal Opportunity clause. The certification may be submitted either for each SUBCONTRACTOR for all subcontracts during a period (i.e., quarterly, semi-annually, or annually).
4. By commencing performance of the Contract work, the selected BIDDER certifies to the Nonsegregated Facilities provisions above.
Company: ______________________________________________ Business Address: ______________________________________________ Signature: ______________________________________________ Name of Signing Official:______________________________________________ Date:__________ Title of Signing Official:______________________________________________ Company Seal (if any):
903
Biofilter Media Replacement & Associated Equipment Inspection
CERTIFICATION OF ANTI-KICKBACK COMPLIANCE
(48 Stat. 948; 62 Stat. 740; 63 Stat. 108; Title 18 U.S.C. § 8741; and 40 U.S.C. (c)) By submission of a Bid, the BIDDER certifies that it has read the “Anti-Kickback Procedures,” referenced above and that neither it nor any of its employees has performed or participated in any prohibited actions, as defined in that provision, relating to the award of the Contract. By commencing performance of the Contract work, the selected BIDDER certifies to Anti-Kickback Compliance.
Company: _____________________________________________
Business Address: _____________________________________________ Signature: _____________________________________________ Name of Signing Official: __________________________________________ Title of Signing Official:____________________________________________ Date: _____________________________________________
Company Seal (if any):
904
Biofilter Media Replacement & Associated Equipment Inspection
CLEAN AIR ACT AND WATER POLLUTION CONTROL CERTIFICATION CLEAN AIR ACT 42 U.S.C. § 7401-7671q.) and the FEDERAL WATER POLLUTION CONTROL ACT as amended
(33 U.S.C. § 1251-1387). 49 CFR, Part 18, Section 18.36) BIDDER agrees that any facility to be used in the performance of the contract, or to benefit from the contract, is not listed on the Environmental Protection Agency List of Violating Facilities.
BIDDER also agrees to comply with all the requirements of Section 114 of the Clean Air Act, as amended, 42 U.S.C. 1857 et seq. and Section 308 of the Federal Water Pollution Control Act, as amended 33 U.S.C. 1251 et seq. relating to the inspection, monitoring, entry, reports and information, as well as all other requirements specified in Section 114 and Section 308 of the Acts, respectively, and all other regulations and guidelines issued thereunder.
BIDDER agrees that as a condition for award of the contract, the BIDDER will notify the awarding official of the receipt of any communication from the EPA indicating that a facility to be used for the performance of, or benefit from, the contract is under consideration to be listed on the EPA List of Violating Facilities.
Company: ______________________________________________ Business Address: ______________________________________________ Signature: ______________________________________________ Name of Signing Official: ______________________________________________ Title of Signing Official: ______________________________________________ Date: ______________________________________________
Company Seal (if any):
905
Biofilter Media Replacement & Associated Equipment Inspection
CONTRACTOR AFFIDAVIT
I, declare under penalty of perjury
(Affidavit’s Name)
under the laws of the State of California and the provisions of the California Labor Code §1771, §1773.1, §1775, §1776, §1777.5, §1813 and §1815 that:
1. I am the of and I
(Officer, Owner, Partner) (Company)
am responsible for the payment of persons employed by
(Company)
who performed work on the City of Visalia Project entitled:
2. During all payroll periods from through , (first work date) (last work date) All persons employed by on this project (Company)
have at all times been paid, at a minimum, the specified general prevailing rate of per diem wages and any amounts due.
3. During all payroll periods on this project, all apprenticeship requirements have been complied with.
Executed and sworn to this day of , (Day) (Month) (Year) ___________________________________ __________________ (Signature) (Date) 906
Biofilter Media Replacement & Associated Equipment Inspection Attachment 4
(begins on next page)
907
Northern Division - Fresno
1210 W. Olive Avenue
Fresno, CA 93728
Telephone (559) 268-1540
Fax (559) 268-0420
Contractor’s License No. 422390
DIR No. 1000001448
Corporate Office: 525 W. Alluvial Avenue, Suite C, Fresno, CA 93711 Telephone: (559) 441-1900 An Equal Opportunity Employer
www.wmlylesco.com
Date: July 24, 2026 Revision: 0
To: City of Visalia
Attention: Ben Litwack and Rehana Cale
Project: Biofilter Media Replacement & Associated Equipment Inspection at Visalia Water Reclamation Facility We are pleased to provide the following proposal for work on the above reference project. We will furnish all labor, equipment, management, and materials for the following:
Bid Item Description Qty Unit Total
1 Mobilization / Demobilization / Site Protection 1 LS $5,000.00 2 Remove & Dispose Existing Biofilter Media (all
beds)
1 LS $66,000.00
3 Surface Cleaning (biofilter walls / floors, trench &
underdrains; pressure cleaning to restore
surfaces)
1 LS $10,000.00
4 Biofilter Media - Furnish, Deliver, Place (100%
screened yard-waste compost overs; see spec)
920 CY $131,560.00
5 Associated Equipment Inspection and
Assessment Only (no routine maintenance)
1 LS $20,000.00
6 Testing & commissioning (smoke test, irrigation
coverage, air balancing report)
1 LS $35,000.00
TOTAL= $ 267,560.00
Scope of Work:
1. Item 1 – Mobilization/Demobilization/Site Protection a. Costs associated with mobilization, Demobilization.
2. Item 2- Remove & Dispose Existing Biofilter Media (all beds) a. Remove, transport, and dispose of existing biofilter media from both cells (Cell A and Cell B) of Biofilter No. 1 (BF01), totaling approximately 6,600 square feet, (920 CY) of effective media surface area at a 3-foot effective media depth, in accordance with all applicable local, state, and federal regulations. b.It is assumed that the existing biofilter media is non-hazardous and able to be disposed of at a local landfill. c. No allowances have been made for that handling and or disposal of hazardous materials.
3. Surface Cleaning (biofilter walls / floors, trench & underdrains; pressure cleaning to restore surfaces) a. Clean accessible surfaces only as necessary to facilitate media replacement; no full reconditioning of structural elements has been allowed.
b.It is assumed that this work can be performed by utilizing a pressure washer to clean the basins. c. No allowances have been made to remove and clean the floor and plenum system
4. Biofilter Media - Furnish, Deliver, Place (100% screened yard-waste compost overs; see spec) a. Furnish & install biofilter media consisting of larger components of typical yard waste composting commonly called “overs” matching the material that was originally installed. b.It is assumed that the installation of the same material originally installed is an acceptable media. c. We were provided pricing for an alternate media that is supposed to be a product that has better performance and longer life span. If this is desired, we can provide it for an additional cost of $132,480.00
1. Scope of supply attached.
908
5. Associated Equipment Inspection and Assessment Only
a. Inspect and assess (no routine maintenance) associated odor control equipment (fans, ducting, dampers, irrigation system, sumps/underdrains, and controls)
b.Inspection shall verify consistency with the design intent and operational requirements identified in these documents, including airflow distribution, material compatibility with corrosive foul air, and functional performance of fans, dampers, and associated controls
6. Testing & Commissioning (smoke Test, irrigation coverage, air balancing) a. Commission and test the system (airflow/smoke test, irrigation coverage, air balancing) and provide documentation
Clarifications
1. This proposal is valid for 30 days from date of this letter.
2. This proposal is based on Plans & Specifications (Attached).
3. This proposal is based on the following Addenda Acknowledged: None
4. Schedule of work is subject to an approved agreeable schedule between the City of Visalia and W. M. Lyles Co.
5.We reserve the right to revise this pricing based on Final Drawings, and Specifications.
6. This proposal is based on mutually agreeable contract terms and conditions.
7. This proposal is based on standard 8-hour workdays. No overtime, weekend, or holiday work has been allowed.
8. This proposal excludes payment and performance bonds. If required, add 0.5% to the price above.
9. This proposal is based on one (1) mobilization. Additional mobilizations will be invoiced on a T&M basis.
10. W. M. Lyles Co. is signatory to the following trades:
a. Laborers
b. Carpenters
c. Operating Engineers
d. Millwrights
e. Cement Masons
Exclusions
1. This proposal is based on the following exclusions:
a. Liquidated damages and/or acceleration.
b. Survey monument preservation/replacement.
c. Survey control points and / or staking.
d. Engineering and/or design.
e. Performance Guarantees.
f. Purchasing of construction water.
g. Purchasing, hauling, and/or disposal of construction and testing water. h. All third-party testing and inspections (WML will coordinate as needed) including but not limited to:
1. Concrete sampling, cylinders, and testing
2. Compaction testing
3. Special inspections.
4. Welding inspections and or testing.
5. Reinforcing steel locating, rebar x-ray, etc.
i. All permits and associated fees including but not limited to:
1. Storm water pollution prevention plan (SWPPP), engineering, permits, plans, BMP implementation and or fee’s.
2. Dust control plan, permits, fees.
3. California Regional Water Quality Control Board permits, fees, discharge requirements.
4. San Joaquin Valley Air Pollution Control District plans and or implementation.
5. Encroachment permits.
j. American Iron & Steel (AIS), Buy America, Buy American, Build America Buy America (BABA) or any similar domestic material requirements.
k. Specific Items Of Work;
1. All Electrical, Instrumentation, and/or SCADA Work.
2. Temporary Bypassing or Pumping.
3. Shut downs, sequencing work, or system bypassing.
4. Hazardous Material surveys and/or testing.
5. Hazardous Material Mitigation / Abatement / Removal / Disposal (if encountered) such as but not limited to Asbestos, Lead, etc.
909
6. Mitigation of Groundwater (if encountered) such as but not limited to, deep well points, piping, bypassing, discharging, etc.
7. Mitigation of Rock (if encountered) such as but not limited to blasting, grinding, drilling, rock trenching, etc.
8. Environmental allowances in the event that special-status plants or species are discovered, or the actions that will be required if such event occurs.
9. Environmental clearances, permitting, arborist, or special requirements for tree removal.
10. Onsite office/construction trailers.
11. Special coatings (chemical resistance, graffiti coatings, etc.)
12. Corrosion Protection / Cathodic Protection such as but not limited to, deep well anodes, test stations, sacrificial anodes, special coatings, etc.
13. Noise mitigation and/or noise barriers.
14. Assessment, removal, repair or replacement of floor and plenum system
15. Assessment, removal, repair or replacement of Liner & Geonet Barrie
16. Assessment, removal, repair or replacement of Irrigation System
17. Assessment, removal, repair or replacement of Drainage Trench Protective Coating General Terms and Conditions:
1. This proposal includes costs for typical insurance policies: General Liability ($2 million/$4 million) and Automobile Liability ($2 million) with additional insured as requested along with standard Worker’s Compensation ($1 million) coverage. Additional insurance coverage that is requested or any payment of deductibles may be at an additional cost.
2. By law, the duty to indemnify shall not extend to the acts of willful misconduct, active, or sole negligence, on the part of the Owner or anyone associated with him including design or engineering work submitted for our Scope.
3. If hazardous materials, unsuitable ground conditions, change in soil conditions or concealed conditions are encountered, we will cease all operations and the Owner will determine the nature and extent of such conditions, and will recommend the nature and extent of remediation. Any hazardous materials, unsuitable ground conditions, change in soil conditions or concealed conditions that are encountered shall be considered “extra work” under an approved Change Order.
4. Any authorized cost plus or force account work shall be completed under written direction per the agreed time and material section within the contractual documents or in absence, using our annual and most current labor and equipment rates along with our time and material calculation sheet.
5. In the absence of Dispute Resolution provisions in the contractual documents, any and all claims, controversies or disputes arising out of or relating to this agreement, or the breach thereof, which remain unresolved after good-faith and direct negotiations between the on-site Project Managers and after with the Corporate Officer(s) and authorized representative of the Owner (parties), shall then be submitted to confidential mediation with written notice in accordance with the rules and procedures for mediation then in effect under either JAMS for Mediation or the Construction Industry Mediation Rules of the American Arbitration Association. Continuing claims, controversies or disputes thereafter shall be submitted to binding Arbitration as allowed by California Law.
6. In the absence of warranty provisions in the Contract Documents, Contractor warrants to Owner that all materials and equipment furnished shall be new unless otherwise specified and that all work under this Agreement will be performed in a good and workmanlike manner, shall be of good quality, free from faults and defects for a period of one (1) year from the date of W.M. Lyles Co.’s scope of work completion.
7. All contractual correspondence and payments shall be directed to our Corporate Office at 525 W. Alluvial Ave., Suite B. Fresno, CA 93711
Thank you for the opportunity in submitting this proposal.
W. M. Lyles Co.
_______________________
Ruben Moreno, Jr.
Project Executive / Secretary
Attachments:
• RFB 25-26-16 Biofilter Media Replacement & Inspection • Exhibit E-1 Visalia WCP O&M Manual ch. 15
• Exhibit E-2 Visalia Specification Vol II of IV - Section 10001 • GES Biotek scope of supply (OPTIONAL MATERIAL)
Contractors are required by law to be licensed and regulated by the Contractor’s State License Board.
Any questions concerning a contractor may be referred to the Register of the board, whose address is:
Contractor’s State License Board, 9835 Goethe Road, P.O. Box 26000, Sacramento, California 95826 910
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
CITY OF VISALIA
REQUEST FOR BID (“RFB”)
RFB NO. 25-26-16
BIOFILTER MEDIA REPLACEMENT &
ASSOCIATED EQUIPMENT INSPECTION
AT VISALIA WATER RECLAMATION FACILITY
BID SUBMITTAL DEADLINE: 2:00PM PT ON THURSDAY, MAY 28, 2026 The City of Visalia expressly reserves the right to modify, or withdraw from, the process initiated and described herein. No rights shall be vested in any party, individual or entity by virtue of its preparation to participate in, or its participation in, such process. The City expressly reserves the right to modify, for any reason, the schedule and any provision contained herein. The City reserves to itself the selection of winning respondent(s), if any, in the exercise of its sole discretion. No binding commitment shall arise on the part of the City to any respondent under this Request for Bid until and unless the parties sign documents of agreement that become effective in accordance with their terms. Responses to this RFB, however, shall be held firm by Respondent for at least ninety (90) days.
This is a Public Works Project, subject to registration with the Department of Industrial Relations (DIR), Payment of State Prevailing Wages, Monitoring by the Labor Commissioner and other requirements listed in the City’s Labor Compliance Manual (attached).
Advertisement Dates: 04/24/26
04/29/26
911
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
TABLE OF CONTENTS
I. DEFINITIONS .......................................................................................................................... 3
II. PROJECT INTRODUCTION ................................................................................................... 3 III. DEPARTMENT OF INDUSTRIAL RELATIONS REQUIREMENTS ...................................... 4 IV. INSTRUCTIONS ...................................................................................................................... 7 V. SCOPE OF WORK/PROJECT SPECIFICATIONS ................................................................ 8 VI. PRE-BID MEETINGS ............................................................................................................. 15 VII. BID OPENING AND CONFIDENTIALITY ............................................................................. 15 VIII. AWARD .................................................................................................................................. 15 IX. PROTESTS/APPEALS .......................................................................................................... 16 X. SPECIAL CONDITIONS ........................................................................................................ 16 XI. GENERAL CONDITIONS ...................................................................................................... 19 XII. POST AWARD RESPONSIBILITIES .................................................................................... 21
EXHIBITS
A. BID FORM
B. CERTIFICATIONS, AFFIDAVITS, ASSURANCES, STATEMENTS, WAIVERS, AND
QUESTIONNAIRES WHICH MUST ACCOMPANY BID FORM
B-1. Bid Guarantee
B-2. Non-Collusion Affidavit
B-3. Worker’s Compensation Insurance Certificate
B-4. Equal Employment Opportunity Compliance Certificate B-5. Ownership Disclosure and Levine Act Statement
B-6. Drug-Free Workplace
B-7. Americans with Disabilities Act Compliance Certificate B-8. Iran Contracting Act
B-9. Certificate of Nonsegregated Facilities
B-10. Certification of Anti-Kickback Compliance
B-11. Clean Air Act and Water Pollution Control Act Compliance Certificate C. SAMPLE PROJECT AGREEMENT WITH ATTACHMENTS
ATTACHMENT 1 - GENERAL CONTRACT PROVISIONS
ATTACHMENT 2 - INSURANCE REQUIREMENTS
D. SAMPLE CONTRACTOR’S AFFIDAVIT
E. ADDITIONAL ATTACHMENTS
E-1. Visalia WRF Q&M Manual, Chapter 15 Odor Control System E-2. City Technical Specifications (Vol II of IV) — Section 10001 Odor Control E-3. State Prevailing Wage Designations
E-4. Labor Compliance Manual
912
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
I. DEFINITIONS
For the purposes of this RFB NO. 25-26-16, the following terms shall have the meanings indicated:
1. “City” means the City of Visalia
2. “City Council” means the Council of the City of Visalia
3. "Bidder", "Vendor", "Supplier", “Consultant”, “Contractor” and “Subrecipient” are used interchangeably throughout this invitation to mean the person, firm, or corporation or other entity submitting a Bid in response to the Request for Bid.
4. “Bid” and “Proposal” are used interchangeably to mean an individual’s or entity’s offer in response to this Request for Bid.
5. “RFB” means Request for Bid No. 25-26-16
II. PROJECT INTRODUCTION
The City of Visalia Purchasing Division is soliciting bids from qualified contractors for a one-time project to remove and replace the odor control biofilter media and conduct an associated equipment inspection at the Visalia Water Reclamation Facility, located at 7579 Avenue 288, Visalia, California. Bids are being sought from contractors who have a proven record of experience in providing the services required by this Invitation to Bid.
Specifications and Bid Documents: Specifications and bid documents may be obtained free of charge at the Purchasing Division, 707 W. Acequia Street, Visalia, California, or by calling (559) 713-4334, or emailing your request to [email protected]. Documents will be emailed to the requestor. If documents exceed email capacity, a share file link will be provided to the requestor so that the documents can be downloaded by the requestor.
Mandatory Pre-Bid Meetings have been scheduled for this project. Bidder’s are required to attend at least one of the mandatory meetings in order to be eligible to bid on project. Meetings will be held at the Water Reclamation Facility located at 7579 Avenue 288, Visalia, CA as follows:
Tuesday, May 12, 2026 at 9:00 a.m. and
Thursday, May 14, 2026 at 9:00 a.m.
Contract Dates: Tentative date of award: June 2026 and Contractor must be able to begin the work as described within this bid upon receipt of the City’s Notice to Proceed. The Notice to Proceed shall be issued in writing by the Purchasing Department.
Time of Completion Deadline: The entire project must be completed within one hundred twenty (120) calendar days from the effective date of the Notice to Proceed. The Notice to Proceed will be issued in writing by the Purchasing Department.
Budget Estimate for this project is approximately $60,000.
Prevailing Wages: Under the requirements of Labor Code section 1782 passed by SB7 and in compliance with City of Visalia Ordinance 2014-13, this public works project is subject to State prevailing wages as specified in document and attachments. Ten (10) days before closing date of the bid, the project manager will review the prevailing wage rates enclosed with this bid for updates. If changes are made, these will be included as an addendum to this bid request. See Section III for additional Department of Industrial Relations Requirements which apply to this project.
License Requirements: No bid will be accepted from a Contractor who is not duly licensed in accordance with the provisions of Chapter 9, Division III of the State of California Business and Professions Code and has a current Class A, General Engineering Contractor’s license. 913
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
Use of Subcontractors: Your proposal may include subcontractors and you should clearly delineate the responsibilities of each of those participants within your proposal. However, the City will recognize the party legally signing the Bid Proposal as prime contractor and contacting party, who, as such, will assume ultimate responsibility for ensuring compliance with the specifications, terms and conditions of the Invitation to Bid. The Prime Contractor must complete a minimum of 30% of the total amount of work under this contract.
III. CALIFORNIA DEPARTMENT OF INDUSTRIAL RELATIONS REQUIREMENTS, Public Works Contractor Registration Program and Project Labor Agreements Notice is hereby given that this is a public works project and therefore, subject to DIR monitoring. All contractors and subcontractors bidding and performing work on Public Works Projects must: Register on an annual basis with the California Department of Industrial Relations (DIR) and furnish electronic payroll records to the Labor Commissioner No contract will be awarded unless that contractor and/or subcontractors are registered with the California Department of Industrial Relations (DIR). Bids submitted by unregistered contractors or that list unregistered subcontractors will be rejected.
A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined in this chapter, unless currently registered and qualified to perform public work pursuant to Section 1725.5. It is not a violation of this section for an unregistered contractor to submit a bid that is authorized by Section 7029.1 of the Business and Professions Code or by Section 10164 or 20103.5 of the Public Contract Code, provided the contractor is registered to perform public work pursuant to Section 1725.5 at the time the contract is awarded.
If a project labor agreement (the term “project labor agreement” is defined in Public Contract Code 2500(b)(1) as a prehire collective bargaining agreement that establishes terms and conditions of employment for a specific construction project or projects and is an agreement described in Section 158(f) of Title 29 of the United States Code) is used, then it must comply with the taxpayer protection provisions set forth in Public Contract Code section 2500(a). City of Visalia has no ordinances requiring or prohibiting such agreements.
The following statements and requirements are to be included in all City of Visalia public work contracts that require the payment of prevailing wages in accordance with California Labor Code (CLC). This RFB document becomes a part of the public works contract for this project and therefore, the CLC contract language requirements are incorporated into the contract. As set forth in CLC section 1771.1(a), all contractors and subcontractors must be currently registered and qualified to perform public work pursuant to CLC section 1725.5 to be qualified to bid, be listed in a bid proposal, or perform any public work for the City of Visalia.
Proof of registration for each contractor and subcontractor listed on the bid is required. As set forth is CLC section 1771.4 (a)(1), notice is given that this project is a public work, subject to compliance monitoring and enforcement by the Department of Industrial Relations.
As set forth in CLC section 1771.4(a)(2), the prime contractor is required by the City of Visalia to post job site notices, as prescribed by regulation. Information on required workplace postings may be found on the Department of Labor website at:
http://www.dir.ca.gov/wpnodb.html .
The contractor and each subcontractor shall maintain all project records required under CLC for public works projects and preserve them for a minimum 3-year period to begin on 914
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
the date a Notice of Completion is filed for the project. Please refer to the retention period required for any grant or specialized project funding. Some funding sources require an extended time period for records retention.
In accordance with CLC section 1773.2, the contractor is required, by the City of Visalia, to post a copy of the determination of the Director of Labor Standards prevailing rate of per diem wages for each craft, classification, or type of worker needed to execute the contract at each job site.
In accordance with labor code section 1776 and it’s enforcement (1771.4(a)(3)), for initial contracts awarded on or after April 1, 2015 each project contractor and subcontractor shall; o Maintain and furnish directly to the Labor Commissioner, bi-weekly, a certified copy of each weekly payroll as specified in section 1776 containing a statement of compliance with labor code sections 1771, 1811 and 1815, signed under penalty of perjury.
o Make available or provide a certified copy of these payroll records and their supporting documentation within 10 days to all authorized parties upon written request and be subject to penalties for non-compliance as detailed in labor code section 1776. o Inform the City of Visalia of the location of the payroll records kept in compliance with labor code section 1776(g) and notify the City of Visalia within 5 working days of any change in their location.
The City of Visalia will comply with any prevailing wage monitoring and enforcement activities required by the labor compliance programs of the Department of Industrial Relations including the withholding of contract payments in the amount of any underpayment of prevailing wage and applicable penalties as directed by the Department of Labor Standards Enforcement in accordance with CLC section 1727(a). Any amount withheld will be released as directed by the Labor Commissioner upon receipt of a certified copy of a final order no longer subject to judicial review in accordance with CLC section 1742(f).
As set forth in labor code section 1775(b), the following subcontractor provisions shall be included in any contract executed between the contractor and a subcontractor for performance of work on this public work project:
o As set forth in CLC section 1775(b)(1), any contract executed between a contractor and a subcontractor for the performance of work on a City of Visalia public works project shall include a copy of the provisions of Labor Code sections 1771, 1776, 1777.5, 1813, and 1815. These labor code sections must be included within or as attachments to the contract.
o As set forth in CLC section 1776, the subcontractor shall maintain and furnish directly to the Labor Commissioner, bi-weekly, a certified copy of each weekly payroll as specified in section 1776 containing a statement of compliance with labor code sections 1771, 1776, 1811 and 1815, signed under penalty of perjury. o As set forth in CLC section 1775(b)(2), the contractor shall monitor the payment of the specified general prevailing rate of per diem wages by the subcontractor to the employees, by periodic review of the certified payroll records of the subcontractor. o As set forth in CLC section 1775(b)(3), upon becoming aware of the failure of the subcontractor to pay his or her workers the specified prevailing rate of wages, the contractor shall diligently take corrective action to halt or rectify the failure, including, but not limited to, retaining sufficient funds due the subcontractor for work performed on the public works project.
915
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
o As set forth in CLC section 1775(b)(4), prior to making final payment to the subcontractor for work performed on the public works project, the contractor shall obtain an affidavit signed under penalty of perjury from the subcontractor that the subcontractor has paid the specified general prevailing rate of per diem wages to his or her employees on the public works project and any amounts due pursuant to Section 1813. Prior to the release of retention to the contractor, the COV will require a copy of the affidavit(s) completed by each listed subcontractor. In accordance with CLC section 1777.5(e), prior to commencing work on a contract for public work; every contractor shall submit contract award information to an applicable apprenticeship program that can supply apprentices to the site of the public work. Only apprentices, as defined in CLC section 3077, in training under apprenticeship standards approved by the Division of Apprenticeship Standards (DAP) and party to written apprentice agreements under CLC section 3070-3098 may be employed at the apprentice wage rate on public works.
Unless exempted under CLC section 1777.5(j), a contractor working on a public works contract of $30,000 or more shall employ the number of apprentices or the ratio of apprentices to journeymen stipulated in the applicable apprenticeship standards (CLC 1777.5(n)). In no event shall the ratio be less than one hour of apprentice work for every five hours of journeyman work.
The prime contractor is responsible for compliance with the requirements of CLC section 1777.5 for all apprenticeable occupations employed on the contract. As stated in 1777.5 (o), the apprenticeship requirement does not apply to contracts of general contractors or to contracts of specialty contractors not bidding for work through a general or prime contractor when the contract is less than thirty thousand dollars ($30,000). As stated in section 1777.7(e), the prime contractor will not be liable for any penalties assessed for violations of section 1777.5 if they have complied with the following requirements:
o The contract executed between the contractor and the subcontractor for the performance of work on the public works project shall include a copy of the provisions of section 1771, 1775, 1776, 1777.5, 1813 and 1815. These labor code sections must be included within or as attachments to the contract. o The contractor shall continually monitor a subcontractors use of apprentices required to be employed on the public works project pursuant to subdivision (d) of section 1777.5, including, but not limited to, periodic review of the certified payroll of the subcontractor.
o Upon becoming aware of a failure of the subcontractor to employ the required number of apprentices, the contractor shall take corrective action, including , but not limited to, retaining funds due to the subcontractor for work performed on the public works project until the failure is corrected.
o Prior to making a final payment to the subcontractor for work performed on the public works project, the contractor shall obtain a declaration signed under penalty of perjury from the subcontractor that the subcontractor has employed the required number of apprentices on the public works project.
The prime contractor is required to provide a signed affidavit declaring their compliance with California Labor Code sections 1771 (prevailing wage) and 1777.5 (apprenticeship) for all workers employed on the contract before final payment will be made on the contract by the City of Visalia.
916
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
Contract inclusion and/or attachments: The following item is required to be included either in the body of, as attachments to, or addendums of all public work contracts:
As set forth in CLC section 1773, the City of Visalia shall obtain the general prevailing rate of per diem wages and the general prevailing rate for holiday and overtime work in the locality in which the public work is to be performed for each craft, classification, or type of worker needed to execute the contract from the Director of Industrial Relations. This will include the apprenticeship prevailing wage for all apprenticeable trades. In accordance with labor code section 1773.2, this information is to be included in the contract itself. 10 days before the closing date of the bid, the project manager will review the prevailing wage rates included in any requests for bid proposals for updates and issue an addendum to notify interested bidders of any changes. General prevailing wage determinations made by the director of industrial relations for journeyman and apprentices may be found at:
http://www.dir.ca.gov/OPRL/PWD/index.htm and
http://www.dir.ca.gov/OPRL/PWAppWage/PWAppWageStart.asp IV. INSTRUCTIONS
1. Fill out attached Bid Form (Exhibit “A”) in ink or typewriting completely.
2. Cross out and initial mistakes in ink and place the correct response next to same.
3. Timely submit Bid in a sealed envelope addressed and marked as follows:
From: Bidder’s Name
Bidder’s Mailing Address
To: City of Visalia Purchasing Division
707 W. Acequia Avenue
Visalia, California 93291
In lower left-hand corner of envelope, mark bid as follows:
PROJECT: Biofilter Media Replacement & Equipment Inspection RFB NO. 25-26-16
BID SUBMITTAL DEADLINE: May 28, 2026 at 2:00pm.
Delivery of Bid: When sending a bid via Fed Ex, UPS, etc., it is the responsibility of the Bidder to ensure that Bid is received during open office hours. Office Hours are 7:30am – 5:00pm Monday through Thursday. We are closed on Fridays and major holidays. Bids are not delivered or received when office is closed.
The City utilizes an outside service for delivery and sorting incoming mail, and therefore, mailing a bid via U.S. Mail is not recommended as there could be a delay in receiving bids by the deadline. Bids must be received prior to the deadline. The City will not accept a postmark as evidence of delivery.
Night Drop Box: If delivering a bid after hours, a Night Drop Box is located at Visalia City Hall, 707 W. Acequia Avenue, Visalia, CA 93291. Enter the west parking lot of the building off of Stevenson Street. The Drop Box is labeled “Night Drop” and is located on the building across from the bicycle racks. The Night Drop Box should only be utilized if City Offices are Closed. The Night Drop Box is checked prior to the bid deadline. 917
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
4. Submit a security deposit of no less than 10% of the Bid amount to the City with the sealed Bid to guarantee the Bid. City will not consider Bids which are not accompanied by the required security. Security may be made by certified check, cashier’s check, or Bidder’s bond. Forfeiture of Bid security shall be governed by California Contract Code Section 20172-20174.
5. Submit each of the required Certifications, Affidavits, Bid Guarantees Assurances, Statements and Questionnaires as well as optional waiver(s) to City with the sealed Bid.
City will not consider Bids which are not accompanied by the required completed forms.
6. Inquiries: Instructions to Vendors, Specifications and Bid Forms may be obtained by visiting our web site at visalia.gov/purchasing or by calling (559) 713-4334. To prevent misinterpretations, the Purchasing Division would prefer that all questions regarding this RFB be sent by email to: [email protected].
Deadline for submitting questions regarding this project is Tuesday, May 19, 2026 at 4:00 p.m.
V. SCOPE OF WORK/PROJECT SPECIFICATIONS
References & Basis of Design:
O&M Manual — Chapter 15 “Odor Control System” (process flow, fans, biofilter overview, operations/maintenance and controls; see Figures 15.1–15.6). See O&M Manual Excerpts below and Exhibit E-1.
City Technical Specifications (Vol II of IV) — specifically Section 10001 Odor Control Biofilters and associated sections for materials, floor system, irrigation, coatings, and testing/commissioning. See Exhibit E-2.
Scope Summary:
The Contractor shall furnish all labor, materials, equipment, and incidentals to:
1. Remove, transport, and dispose of existing biofilter media from both cells (Cell A and Cell B) of Biofilter No. 1 (BF01), totaling approximately 6,600 square feet of effective media surface area at a 3-foot effective media depth, in accordance with all applicable local, state, and federal regulations. All disposal costs shall be the responsibility of the Contractor and shall be included in the bid price. The Contractor shall provide the City with disposal manifests documenting the quantity and disposal location of all removed media prior to final payment. Following removal, replace with new media meeting the specifications set forth herein;
2. Inspect and assess (no routine maintenance) associated odor control equipment (fans, ducting, dampers, irrigation system, sumps/underdrains, and controls);
3. Clean accessible surfaces only as necessary to facilitate media replacement; no full reconditioning of structural elements is required;
4. Commission and test the system (airflow/smoke test, irrigation coverage, air balancing) and provide documentation.
918
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
This is a one-time project limited to media replacement and inspection; no ongoing or annual maintenance is included.
Biofilter System — Key Technical Requirements:
A. Floor & Plenum System
The existing modular floor and plenum system shall remain in place and shall not be replaced unless determined to be unusable through inspection and authorized in writing by the City. If it is determined that the floor and plenum system needs to be replaced, the Contractor shall replace the modular HDPE/PP perforated floor plates and all associated components to meet the following requirements:
o Modular HDPE/PP perforated floor plates installed over reinforced concrete slab with a minimum 5-inch air plenum between the concrete and underside of plates. Static pressure drop ≤ ¼″ w.c. at 10 cfm/ft²; tapered openings (narrowest at top). Structural capacity to support a 25,000 lb rubber-tired backhoe loader (≈100 psi wheel pressure).
The Contractor shall not assume replacement of the floor and plenum system in the base bid; any such work shall be performed only upon written authorization by the City.
B. Liner & Geonet Barrier
The existing liner and geonet barrier shall remain in place and shall not be replaced unless determined to be unusable through inspection and authorized in writing by the City. If it is determined that the liner and/or geonet barrier needs to be replaced, the replacement shall meet the following requirements:
o PVC liner: 40 mils, specific gravity 1.2–1.3; field welded and tested per manufacturer recommendations (AccuGeo or equal).
o Tri-planar geonet barrier (e.g., Tenax Tendrain TD5 or equal): 275 mil thick, density ~0.94 g/cc; tensile strength ~13 kN/m; compression retention ~65% @ 1,200 kp; typical openings ≈0.25″×0.35″; 12″ overlap at joints. No full removal or replacement of liner or geonet is included in the base scope.
C. Biofilter Media (Compost “Overs”)
Media shall be 100% screened yard waste compost overs, particle size 2–6″, with ≥90% between 2–4″, pH 6–8, debris ≤1% by weight, stabilized, and free of objectionable odors; place loosely (no compaction) to an effective depth of 3.0 ft, allowing ~9″ for initial settling/cure.
Submittals: Provide media gradation reports and a cubic foot sample of the proposed media before procurement/placement.
D. Irrigation System (Hydration & Coverage)
The existing irrigation system shall remain in place and shall not be replaced or rehabilitated unless individual components are determined to be non-functional through inspection and authorized in writing by the City. If it is determined that irrigation system components need to be replaced, the replacement shall meet the following requirements:
o Zone controlled irrigation consisting of PVC mains/headers (typ. 1″ header per cell, 5/8″ connections), gear-driven pop-up sprinklers (ABS), and an inbed drip grid (polyethylene tubing with ~0.6 gph emitters, Netafim or equal), strainers, PRVs, and drains to achieve complete and uniform coverage across the media surface.
o Controller: ESP MC series (Rain Bird or equal) in NEMA 4X enclosure, 120 VAC in / 24 VAC out, ≥8 zones, fully programmable.
Work under this section is limited to inspection and minor adjustments necessary to support media establishment; full system rehabilitation is not included. 919
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
E. Drainage Trench Protective Coating
The existing trench protective coating shall remain in place and shall not be recoated unless determined to be unusable through inspection and authorized in writing by the City. If it is determined that the trench coating needs to be replaced, the replacement shall meet the following requirements:
o SprayWall (or equal) polyurethane coating applied to the central drainage trench at 120 mils DFT; VOC free; holiday testing per NACE PRO188-99; adhesion per ASTM D4541 (150–200 psi); 10-year warranty. No full recoating is included in the base scope; recoating shall only occur if existing coating is deemed failed or unusable and authorized by the City.
F. Fans / Ducting / Dampers
Inspect foul air FRP/HDPE/PP ductwork, centrifugal fans, and dampers per City of Visalia Technical Specifications, Volume II of IV, including Section 10001 – Odor Control Biofilters and related sections governing odor control systems, materials, and equipment, and O&M Manual Chapter 15 – Odor Control System (including Figures
15.1–15.6 and Table 15.1).
Inspection shall verify consistency with the design intent and operational requirements identified in these documents, including airflow distribution, material compatibility with corrosive foul air, and functional performance of fans, dampers, and associated controls.
No routine servicing or maintenance is required; repairs or replacement shall only occur if components are determined to be non-functional and with prior City authorization.
Execution and Contractor Responsibilities:
A. Removal & Cleaning
Remove, transport, and dispose of existing biofilter media from BF01 (both cells) in accordance with all applicable local, state, and federal regulations; clean structural surfaces including biofilter walls/floors, trench surfaces, and underdrains/sumps as necessary to facilitate media replacement and inspection; all disposal costs shall be included in the bid price, and disposal manifests shall be provided to the City prior to final payment.
Cleaning shall be limited to what is necessary to facilitate media replacement and inspection; full surface restoration is not required.
B. Installation
No installation or replacement of liner, geonet, trench coatings, or structural system components is included in the base scope.
Existing liner, geotextile, underdrain system, and trench coatings shall remain in place and shall not be replaced as part of this work unless determined to be unusable through inspection and authorized in writing by the City. Place media loosely; pre wet and cure the bed to field capacity; keep moist for ≈3 weeks prior to full operation.
Irrigation system adjustments may be performed to support media establishment; full system reconstruction is not included.
C. Associated Equipment Inspection Only
Inspect fans (belts/bearings), dampers (linkages/actuators), ducting (leaks/cracks), sumps/pumps, and irrigation controls.
No preventive or routine maintenance shall be performed. Repair or replacement of components shall only occur if deemed unusable or nonfunctional and only upon prior City approval. 920
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
No maintenance allowance is included in the base scope.
D. Start-Up & Testing
Smoke test & airflow verification across the beds; adjust dampers/fans for even distribution.
Irrigation coverage check and adjustments (zone timing, emitter/sprinkler performance).
Air balancing: submit a formal air balance report (record flows, pressures, fan speeds, amperage) consistent with City testing requirements. Submit a commissioning package (photos, test data, settings, O&M notes).
E. Documentation & Submittals
Required Submittals: Media gradation reports; cubic foot sample of proposed biofilter media; final air balance report; and commissioning documentation (including test data, photos, and system settings).
Conditional Submittals (only if repair or replacement work is authorized by the City):
Shop drawings and irrigation layout/schematics; product data and samples for liner and geonet materials; trench coating data (including manufacturer specifications and testing requirements); and any additional submittals associated with the approved repair or replacement work.
F. Work Sequencing & Continuity of Service
Coordinate with Plant Operations to maintain odor-control service; submit a staging plan showing bed-by-bed sequencing, temporary controls, and expected durations. (Per O&M Ch. 15, system components and controls must remain operable during normal operations.)
Safety & Environmental:
Dust/runoff control; proper handling of compost media; liner/coating application per manufacturer safety data; electrical LOTO on fans/controls; disposal per City/environmental regulations. (General compliance drawn from the City’s technical specification framework.)
Change Orders / Additional Work:
If, during the course of inspection or construction, the Contractor identifies any components that are unusable or require repair or replacement beyond the base scope, the Contractor shall provide a detailed, itemized cost proposal for the additional work. The proposal shall include, at a minimum:
o Labor (by classification and hours)
o Materials (quantities and unit costs)
o Equipment
o Subcontractor costs (if applicable)
o Overhead and profit
No additional work shall proceed without prior written authorization from the City. All proposed changes shall be reviewed and approved by the City’s Change Order Committee prior to commencement of the work.
Failure to obtain written authorization prior to performing additional work shall result in non-payment for such work.
At the conclusion of the work, Awarded Contractor shall provide the City of Visalia Project Manager with a signed Contractor’s affidavit that labor codes were followed, and prevailing wage rates were paid. The affidavit must be submitted to the City Project Manager prior to final payment. A sample Contractor’s Affidavit is included with this RFB (see Exhibit D).
Awarded Contractor shall follow the requirements of the City of Visalia Labor Compliance Manual (which is made a part of this RFB and contract). 921
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
O&M Manual Excerpts:
Odor Control System Process Flow Diagram (Figure 15.1)
922
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
Foul Air Supply Fans (Figure 15.2)
Biological Filter (Figure 15.3)
Biofilter Fan HOA Selector Switch (Figure 15.4)
923
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
Irrigation System Selector Switch (Figure 15.5)
Partial Single-Line Diagram for Biofilter Fans (Figure 15.6) 924
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
VI. PRE-BID MEETINGS
1. Mandatory Pre-Bid Meetings have been scheduled for this project. Bidder’s are required to attend at least one of the mandatory meetings in order to be eligible to bid on project.
Meetings will be held at the Water Reclamation Facility located at 7579 Avenue 288, Visalia as follows:
Tuesday, May 12, 2026 at 9:00 a.m. and
Thursday, May 14, 2026 at 9:00 a.m.
Information on the project will be available during the meetings and time is designated for Contractors to ask questions about the work/contract. It shall be the responsibility of the Contractor to have acquired full knowledge of the job site, scope of work and any problems or difficulties that may affect the work proposed.
VII. BID OPENING AND CONFIDENTIALITY
1. Bid Opening. Bids shall be opened publicly in the presence of attendees, if any, on May 28, 2026 at 2:00 p.m. at 707 W Acequia, Visalia CA, City Hall. The name of each Bidder and the amount of each Bid shall be read aloud and summarized on a Bid Summary sheet. The bid summary sheet is open to public inspection at the Bid opening and after the City has made an Intent to Award decision. Other Bid information will not be available for public review during the evaluation phase.
2. Bid Confidentiality. The City favors full and open disclosure of all Bid records. The City will not expend public funds defending claims for access to, inspection of, or to be provided copies of any such records. By submitting a Bid, a Bidder agrees to indemnify and defend the City against all claims or actions brought against it to seek access to, or compel disclosure of, any records or documents in the City’s possession.
After the award, the City intends that its selection process will be open and public.
Respondents are advised that the California Public Records Act (“PRA”) provides that any person may inspect or be provided a copy of any identifiable public record or document that is not exempted from disclosure by the express provisions of the Act. The Federal Freedom of Information Act (“FOIA”) contains a similar provision. Each Bidder shall clearly identify any information within its Bid that it intends to ask the City to withhold as exempt under either the PRA or FOIA. Any information contained in a Bidder’s submission which the Bidder believe qualifies for exemption from public disclosure as “Proprietary” or “Confidential” must be identified as such at the time of first submission of Bidder’s Bid to this RFB. Any failure to identify information contained in a Bidder’s Bid to this RFB as “Proprietary” or “Confidential” shall constitute a waiver of Bidder’s right to object to the release of such information upon request under either Act.
VIII. AWARD
1. Most Responsive, Responsible Bidder. A Contract (substantially similar to that attached hereto as Exhibit “C” with Attachments 1-2) shall be awarded with reasonable promptness by appropriate written notice. Award shall be made to the lowest bidder whose bid is deemed both responsive and responsible and meets the criteria and specifications set forth in this RFB. A responsible Bidder is one who has the capability, financial capacity and integrity to perform the contract. A responsive Bidder is one who commits to all of the material terms, for example, price, quantity, quality and delivery, of this RFB. Contractor must return a signed copy of the contract provided by the City with its Award Notice to City within ten (10) working days of receipt thereof. 925
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
2. Reservation of Rights. The City reserves the right to reject any item or items in the Bid; to waive informalities, technical defects, and minor irregularities in Bids received; and to select the Bid(s) deemed most advantageous to the City.
IX. PROTESTS/APPEALS
Because it is essential that Bidders have confidence in the procurement procedures for soliciting and awarding contracts, it is the policy of the City to offer Bidders the opportunity to appeal award of contracts. The following procedures shall apply in regard to appeals:
1. Any actual Bidder who is aggrieved in connection with this RFB or award of a contract hereunder may protest to the City of Visalia Purchasing Division in writing within five (5) working days after such aggrieved Bidder knows, should have reasonably known, or could reasonably be expected to know of the facts giving rise thereto; and
2. Should identify only the areas regarding bid contradictions, procurement errors, quotation rating discrepancies, legality of procurement context, conflict of interest in the rating process and inappropriate or unfair competitive procurement grievance regarding the Bid process.
3. The City’s Purchasing Division shall have the authority to settle and resolve each protest.
The resolution will be provided to Bidder in writing within five (5) working days of receipt of the appeal unless the Bidder is notified more time is required.
4. Further levels of appeal may be made in accordance with the appeals provision contained in Chapter 5 of the City’s “Purchasing and Contract Procedures” which is available through City’s Purchasing Division.
X. SPECIAL CONDITIONS
1. Project Administrative Issues
a. Complete Project. The successful Bidder shall be responsible for providing all materials, taxes, labor, equipment and services necessary to fulfill the requirements of this RFB. It is the intent of this RFB and related agreement to describe a functionally complete project.
b. Quantities/Change Orders. The City reserves and shall have the right to make such changes to the work as may be necessary and desirable to complete the work originally intended in an acceptable manner. Unless otherwise specified herein, the Project Manager shall be and is hereby authorized to make such changes, in the work as may increase or decrease the originally awarded contract quantities and/or total contract cost. The Contract Price, or the amount due the Contractor will only be reduced/increased after the price change is reviewed and authorized by the City of Visalia Change Order Committee.
Should the Contractor disagree with any terms or conditions set forth in an approved contract change order not executed by the Contractor, the Contractor shall submit a written protest to the Project Manager within 15 days after the receipt of the approved contract change order and the procedures outlined in Section 4-1.03 of the Standard Specifications apply.
If a requested change order is sent back to the Contractor for revisions, the Contractor has 15 (fifteen) calendar days to resubmit.
926
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
Changes shall not invalidate the contract nor release the surety, and the Contractor agrees to accept payment for such changes as if the altered work had been a part of the original contract. These changes which are for work within the general scope of the contract shall be covered by Change Orders issued by the City. Change orders for altered work shall include extensions of contract time where, in the Project Manager’s opinion, such extensions are commensurate with the amount and difficulty of added work.
Excessive altered work shall be covered by supplemental agreement that is subject to funding agency approval as applicable. If the City and the Contractor are unable to agree on a unit adjustment for any contract item that requires a supplemental agreement, the City reserves the right to terminate the contract with respect to the item and to make other arrangements for its completion.
c. Omitted Items. Project Manager is authorized to omit minor contract items. Major items must be omitted by supplemental agreement.
d. Extra Work. Contractor is prohibited from doing extra work, unless authorized in writing by Project Manager before the work is done. The Project Manager should obtain authorization from the Change Order Committee before agreeing to extra work requested by the Contractor. In the instances where it is necessary for the work to be done immediately, the Project Manager may authorize the work prior to taking the additions to the Change Order Committee. Payment for approved Extra Work shall be as agreed to in writing by the Project Manager prior to the Extra Work being completed or the Change Order Committee shall approve an increase in a Change Order issued after the Extra Work is completed. No additional payment is due for unauthorized Extra Work.
If the Project Manager authorizes Extra Work but the payment for the Extra Work has not been agreed to in writing prior to the work being completed, then Contractor shall submit to the Project Manager the documentation required for a Change Order within forty-five (45) days of completing the Extra Work. The Project Manager will submit a Change Order request for review and approval by the Change Order Committee. If the Contractor does not submit any documentation within that time period the Project Manager may move forward with issuing a Change Order to adjust the contract price. e. Removal of Obstructions. Contractor shall remove and dispose of all structures, debris or other obstructions of any character required for completion of the project. Any temporarily removed or relocated items shall be replaced. f. Clean Up. Prior to acceptance and final payment, Contractor shall clean up the site of work, and any areas occupied by Contractor in connection with the project.
2. City-Contractor Relations
a. Project Manager’s Responsibility and Authority. City will designate a Project Manager.
All work shall be done under the general supervision of such Project Manager or his or her designee(s). The Project Manager shall decide issues of quality and acceptability of materials, work performance, rate of progress of work, interpretation of drawings and specifications, and all questions related to fulfillment of the contract for the project.
Project Manager shall not have control over acts or omissions of the Contractor, Subcontractors, their agents or employees.
b. Contractor/Contractor’s Superintendent. Contractor shall bear all responsibility for, and have all control over, the construction means, methods, techniques, sequences, procedures and safety precautions or programs related to the project. Contractor may designate a superintendent.
c. Project Site/Existing Utilities and Structures.
927
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
(1) Contractor shall take care to avoid, but shall be responsible for, all damage to existing structures, including, but not limited to, sewers, water service, drains and culverts, underground utilities and the like.
(2) USA Notification. Contractor shall notify underground service alert (“USA) of times and locations of proposed excavations.
i. Contractor shall notify owners of and be responsible for damage to utilities and substructures.
ii. If damage occurs to an unknown utility, Contractor shall repair the utility. iii. Contractor shall not make connection to or draw water from any hydrant or pipeline without first obtaining permission to do so.
d. Signs, Barricades, and Notice. Contractor must provide and maintain proper barricades, fences, signal lights, watchmen, and notice in general to the surrounding public, in accord with local, federal, and state requirements. e. Labor
(1) Workmanship. Workmanship shall be equal to the best general practice of modern day fabrication shops and good construction practice. (2) Qualification. Contractor shall ensure that each employee who works on this project is qualified to perform their assigned duty in a safe manner. f. Control of Materials:
(1) Source of Supply and Quality of Materials Guarantee. All materials, parts and equipment supplied by the Contractor shall be new and of a quality equal to that specified. Materials which become unfit for use shall not be used for the project. (2) Equivalent Materials. Trade names or manufacturer’s catalog information, where used, are a means of indicating kind, type, design, style, finish, durability or quality desired and are not intended to exclude or omit the products of any responsible manufacturer, if such products are equal in every respect to those specified. The burden of proof of compliance with the specifications is the responsibility of Contractor. City shall be the sole judge as to the adequacy of any item for substitution.
(3) Manufacturer’s Directions. Manufactured articles, materials and equipment shall be applied, installed, connected, erected, used, cleaned and conditioned as directed by the manufacturer.
g. Storage of Materials. Materials shall be stored to ensure the preservation of their quality and fitness for the project.
h. Materials and Shop Drawing Submittals. If applicable, Contractor shall submit to Project Manager for approval, two (2) copies of the materials list and detailed dimensional shop drawings covering all Contractor-furnished items of equipment.
Prior approval by Project Manager is required. Such approval shall not relieve the Contractor from the responsibility of deviation from the Contract unless Contractor has, in writing, called to the attention of the Project Manager such deviations.
3. Legal Responsibilities.
It is the responsibility of Contractor to comply with all local, state, and federal laws and regulations which apply to this project. This includes, but is not limited to, compliance with Uniform Building, Plumbing, Mechanical, Electric, and Fire Codes.
Contractor shall provide a safe working environment in compliance with the Occupational Safety and Health Act, and California Health and Safety Codes. 928
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
Additionally, Contractor shall secure all necessary permits, licenses, and similar requirements to carry out the project. Contractor shall comply with all applicable labor laws, and ensure against discrimination.
XI. GENERAL CONDITIONS
1. It is the policy of the City to provide equal opportunity to all candidates when selecting Bidders to provide public services. Bidders are expected to be equal opportunity employers.
The City hereby affirmatively ensures that Minority Business Enterprises and Disadvantaged Business Enterprises (DBE) will be afforded full opportunity to submit proposals in response to this notice. Individuals and/or entities submitting bids/proposals to the City of Visalia will not be discriminated against on the basis of race, religion, color, national origin, ancestry, physical or mental disability, medical condition, genetic information, marital status, gender, gender identity or expression, sexual orientation, or military and veteran status in any consideration leading to the award of contract.
No qualified disabled person shall, on the basis of disability, be excluded from participating in, be denied the benefits of, or otherwise be subjected to discrimination under any program or activity that receives or benefits from Federal financial assistance.
Bidder shall provide to the City a list of all instances within the last ten (10) years where a complaint was filed or pending against Bidder in a legal or administrative proceeding alleging that Bidder discriminated against its employees, subcontractors, vendors or suppliers. A description of the status or resolution of that complaint, including any remedial action taken is required.
2. Post-Closing Date Corrections are prohibited.
3. Bids will not be accepted unless signed in ink (not typed) in the appropriate space(s) by an authorized officer or employee of the Bidder.
4. Bids must be submitted on or before the Closing Date. Any Bids received after the Closing Date shall be returned, unopened, to the Bidder, provided the request number, opening date, and Bidder's return address are on the envelope.
5. Bids may be withdrawn prior to the Bid Closing Date by writing to the Purchasing Division.
6. Telegraphic, telephonic, electronic and facsimile Bids and withdrawal requests will not be accepted.
7. Prices submitted are considered accurate for a period of ninety (90) days and cannot be withdrawn after the Closing Date.
8. All Bids are the property of the City after submission.
9. City is not responsible for Bid errors and omissions.
10. Bids should be prepared in a straightforward, concise manner. Information provided which was not specifically requested will be considered only in City’s discretion.
11. A written amendment or addenda issued by City’s Purchasing Division is the only method which should be relied on with respect to changes to the RFB. Respondent is 929
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
responsible to contact City’s Purchasing Division prior to submitting a Bid to determine if any amendments were made to the RFB.
12. Any contract resulting from the RFB will be jointly administered by the City’s Purchasing Division, and the Department requesting Bids.
13. Prior to conducting business in the City, a business tax certificate (license) must be obtained. Call 559-713-4326 for more information.
14. Bidder shall provide insurance as required by law and as indicated in the proposed contract.
15. Bidder shall maintain all personnel files and payroll records for employees used to implement the proposed contract.
16. Bidder shall withhold, pay and report all taxes and issue W-2 forms at the end of each calendar year for employees used to implement the proposed contract.
17. Pursuant to the City’s Charter, all other things being equal, tie Bids shall be awarded to a local merchant to the extent quality and prices are equal. If neither is a local vendor, the Bid shall be awarded by the flip of a coin by the Purchasing Division in the presence of at least one witness.
18. The City may make such investigation of the Bidder and information in the Bid as it determines necessary. This may include the collection of criminal history information, contractual and business associations and practices, employment histories and reputation.
19. All California agencies may purchase off the Proposal submitted at the same prices, terms, conditions and specifications. The City of Visalia shall incur no responsibility in connection with another agency’s purchase.
20. Each Bidder, will be required to submit Certifications, Affidavits, Bid Guarantees, Assurances, Statements and Questionnaires which are attached in Exhibit “B”.
21. The quantities given on the Bid Proposal form and any related contract documents are approximate only. They are given as a basis for comparison of Bids. The City of Visalia does not, expressly or impliedly agree that the actual amount of work will correspond therewith, but reserves the right to increase or decrease the amount of any class or portion of work, or to omit portion of the work, as the City deems necessary or advisable, at the prices Bid.
22. Bidders shall satisfy themselves by personal examination of the work site, specifications, plans, and other contract documents, and by any other means as they believe necessary, as to the actual physical conditions, requirements, and difficulties under which the project must be performed. The submission of a Bid shall be conclusive evidence that the Bidder has investigated, and is satisfied as to the conditions encountered, as to the character, quality, and quantities of work to be performed, and the materials to be furnished, and as to the requirements of the RFB and the City. No allowance shall subsequently be made because of lack of such examination or knowledge.
23. All Bidders are required to make a Bid on the complete Bid Form (Exhibit “A”).
Contractor may be required to submit Proposals on alternate items. The City reserves the right to award the contract based on the lowest combination or combinations of Proposal items and alternate proposed items.
24. Bid Form may specify a line item for sales tax. When the Bid Form does not contain a line item for sales tax, no mention shall be made in the Proposal of sales tax, use tax or 930
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
any other tax, as all amounts Bid will be deemed and held to include any such taxes, which may be applicable.
25. Only one Bid may be submitted as a “Prime Contractor” for the same work by any firm, individual, partnership, corporation or combination thereof. A Contractor submitting a Bid as a Prime Contractor may not also submit sub-Bids to other competing Prime Contractors. Reasonable grounds for believing that any individual, firm, partnership, corporation or combination thereof is interested in more than one Proposal for the work contemplated will cause the rejection of all Proposals in which such individual, firm, partnership, corporation or combination thereof is interested. A Contractor who is not submitting a Bid as a Prime Contractor may submit any number of sub-Bids to competing Prime Contractors.
26. The City of Visalia is not liable for any costs incurred by Bidder in responding to this Request for Bid.
27. EXECUTIVE ORDER N-6-22 – Russia Sanctions - On March 4, 2022, Governor Gavin Newsom issued Executive Order N-6-22 (the EO) regarding Economic Sanctions against Russia and Russian entities and individuals. “Economic Sanctions” refers to sanctions imposed by the U.S. government in response to Russia’s actions in Ukraine, as well as any sanctions imposed under state law. By submitting a bid or proposal, Contractor represents that it is not a target of Economic Sanctions. Should the State determine Contractor is a target of Economic Sanctions or is conducting prohibited transactions with sanctioned individuals or entities, that shall be grounds for rejection of the Contractor’s bid/proposal any time prior to contract execution, or, if determined after contract execution, shall be grounds for termination by the State.
XII. POST AWARD RESPONSIBILITIES
1. Written Contract with City. A written agreement in a form similar to that attached to this Request for Bid as Exhibit “C” with Attachments 1-2 must be entered into between the City and the Contractor to whom the project is awarded. The Agreement forms the basis for the contractual obligation between the parties regarding the project. A contract will be provided with the Notice of Award and must be executed and returned to City within ten (10) working days of the date of award notification unless otherwise agreed.
2. Post Award Meeting. Subsequent to the award of contract, the Contractor shall meet with the Project Manager prior to the start of work to discuss any problems or questions that may arise. Contractor shall contact the Project Manager within ten (10) days of the date of the Notice to Proceed to arrange this meeting.
City Project Manager: Rehana Lustyan
Department: Public Works – Water Reclamation Facility
3. Post-Award Responsibilities. Upon execution of the Agreement between the City and the Contractor, the Contractor shall immediately report all changes in its Articles of Incorporation, By-Laws, or Tax-Exempt status to the City.
4. Insurance. Contractor shall obtain and maintain the minimum insurance coverage outlined Exhibit “C”, Attachment 2. Contractor shall provide evidence of such insurance to City’s Purchasing Division prior to commencement of work on the project.
5. Required Bonds: The Bidder(s) awarded contract(s) pursuant to this RFB will be required to provide to the City of Visalia: 1) a “Performance Bond” and 2) a “Payment Bond”, each in the amount of 100% of the contract amount within ten (10) working days of the date of the “Notice of Award”. According to City standard the surety company must be a California Admitted Surety to its specified dollar limitation AND a current A.M. Best 931
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
A: VIII rated surety. The Performance bond shall remain in force for one year after the date of completion.
Contractor shall provide a One year “Maintenance Bond” in the amount of 10% of the contract amount. Maintenance Bond shall be submitted to the Project Manager prior to final payment request. Maintenance period shall begin at project completion date and remain in effect for one year
Upon determination by the City that a contract has been entered and Contractor has provided all of the information that it is required to provide pursuant to this RFB, City will issue, in writing, a notice to proceed on the project to Contractor. 932
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
BIDDING AGENCY:_________________
EXHIBIT “A”
BID FORM RFB NO. 25-26-16
Project: BIOFILTER MEDIA REPLACEMENT & ASSOCIATED EQUIPMENT INSPECTION AT
VISALIA WATER RECLAMATION FACILITY
TO: THE CITY OF VISALIA PURCHASING DIVISION:
In compliance with the City’s Notice Inviting Sealed Bids No. 25-26-16 dated: __________, the undersigned BIDDER hereby proposes to furnish all materials, taxes, equipment, tools, labor appurtenances and incidentals required for the above stated project as set forth in the RFB, including all Exhibits and related contract documents therefore, and to perform all work in the manner and time prescribed therein.
BIDDER declares that this proposal is based upon careful examination of the work site, Instructions to BIDDERs, and the contract requirements. If this proposal is accepted for award, BIDDER agrees to enter into a contract with CITY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the time and manner prescribed will result in forfeiture to the City of the Bid Guarantee accompanying this proposal.
BIDDER understands that a bid is required for the entire work and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties and fees. In the case of discrepancies in amounts bid, unit prices shall govern over extended amounts.
BIDDER hereby agrees to execute a contract and provide bonds within ten (10) working days, or such further time as may be allowed in writing by the Purchasing Division, after receiving notification of the acceptance of this Bid, and it is hereby mutually understood and agreed that in case the BIDDER does not, the accompanying Bid Guarantee shall be forfeited to the City of Visalia as liquidated damages, and said Purchasing Division may proceed to award the contract to others.
BIDDER agrees to commence the work within ten (10) calendar days after the effective date of the Notice to Proceed and to complete the work within one hundred twenty (120) calendar days, unless extended in writing by the Purchasing Division.
BIDDER shall pay the City LIQUIDATED DAMAGES in the amount of seven hundred fifty dollars ($750) a day for each calendar day the project is delayed beyond the “TIME OF COMPLETION DATE”.
BIDDER proposes to furnish a Payment Bond in the amount of one hundred percent (100%) and a Performance Bond in the amount of one hundred percent (100%) of the agreement, as surety condition for the full, complete and faithful performance of the agreement. In addition, Contractor shall furnish a Maintenance Bond in the amount of 10% of the agreement, prior to final payment request. Maintenance period shall begin at project completion date and remain in effect for one year. According to City standards the surety company must be a California Admitted Surety to its specified dollar limitation AND a current A.M. Best A: VIII rated surety.
BIDDER agrees to abide by all requirements of the Department of Industrial Relations (DIR) applicable to this public works contract and specified in the City of Visalia Labor Compliance Manual, including but not limited to assuring valid DIR registration numbers for all Contractors and Subcontractors performing work under this contract, payment of state prevailing wages, and uploading certified payrolls to the Labor Commissioner. 933
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
BIDDING AGENCY:_________________
BIDDER further declares that he/she has not either directly or indirectly entered into any agreement, participated in any collusion, or otherwise taken any action in restraint of free competitive bidding in connection with said bid.
LOWEST BID WILL BE BASED ON THE LOWEST TOTAL BID AMOUNT. Bid will be awarded to the lowest bidder whose bid is deemed both responsive and responsible and meets all specifications of RFB 25-26-16.
BIDDER has read and hereby agrees to the conditions stated in this proposal by affixing his/her signature on bid form.
Instructions: Bidder shall enter Unit Price and Extended Amount for each item. If a discrepancy exists between unit price and extended amount, the unit price controls. Totals include all labor, materials, taxes, equipment, incidentals, overhead, and profit.
No.
Item Description
(Per specifications of
RFB 25-26-16)
Unit
Estimated
Quantity
(A) x
Unit Price
(B) =
Extended
Amount
(C)
1 Mobilization /
Demobilization / Site
Protection LS 1 x $ = $
2 Remove & Dispose Existing
Biofilter Media (all beds) LS 1 x $ = $
3 Surface Cleaning (biofilter
walls/floors, trench &
underdrains; pressure cleaning
to restore surfaces)
LS 1 x $ = $
4 Biofilter Media – Furnish,
Deliver, Place (100% screened
yard-waste compost overs; see
spec)
CY 920 x $ = $
5 Associated Equipment
Inspection and Assessment
Only (no routine maintenance) LS 1 x $ = $
6 Testing & Commissioning
(smoke test, irrigation
coverage, air balancing report)
LS 1 x $ = $
TOTAL BID AMOUNT
(Items 1-6)
$
Notes:
Required submittals include media gradation reports, cubic foot sample of proposed biofilter media, final air balance report, and commissioning documentation (including test data, photos, and system settings). Media submittals (gradation & sample) shall be approved prior to mobilization.
Conditional submittals (only if repair or replacement work is authorized by the City) include shop drawings and irrigation layout/schematics; product data and samples for liner and 934
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
geonet materials; trench coating data; and any additional submittals associated with the approved work.
Air balance report and full commissioning package are required at closeout. All work shall maintain odor control service via staged construction and coordination with Operations (see O&M Ch. 15).
This contract is limited to one-time media replacement and inspection; no ongoing or annual maintenance is included.
(1)________________________________________________________________________________________ Bidding Agency
(2)______________________________________________________________________________________ Corporation, Partner, Joint Venture
(3)______________________________________________________________________________________ Business Address City State Zip Code
________________________________________________________________________________________ Telephone Number Email Address
(4)____________________________________________________________________________________________ Signature of Authorized Person (Date)
____________________________________________________________________________________________ Type or Print Authorized Person’s Name
PLEASE SEE THE FOLLOWING INSTRUCTIONS REGARDING SIGNATURE (1) If the BIDDER is an individual, enter name here in style used in business; if a joint venture, exact name of entities joining in the venture; if a partnership, the correct trade style of the partnership; if a corporation, the exact name of the corporation. (2) If BIDDER is other than an individual, identify here its character, i.e., joint venture, partnership, corporation, including the state of incorporation. If BIDDER is an individual operating under a trade name, state “an individual dba (trade name in full)”. (3) State on this line, the address to which all communications and notices regarding the Bid Proposal, and any contract awarded thereunder, are to be addressed. (4) If BIDDER is a joint venture, signature must be by one of the joint venturers, and if one or both of the joint venturers is a partnership or a corporation, each participating partnership must sign by a general partner, and each corporation by an authorized officer or employee; if a partnership, by a general partner; if a corporation, by an authorized officer or employee. The title of the person signing must appear after his/her signature. Where BIDDER is a partnership or corporation, the names of all other general partners, or the president or secretary of the corporation and their business addresses must be shown below. ______________________________________________________________________________________________ ______________________________________________________________________________________________ ______________________________________________________________________________________________ _________________________________
Note: All names must be typewritten under written signature. All Addresses must be complete with street number, city, state and zip code.
935
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
BIDDING AGENCY:_________________
BIDDING CONTRACTOR’S LICENSE INFORMATION:
STATE CONTRACTOR’S LIC. CLASS:_________________ # _____________________________EXP. DATE:___________ STATE D.I.R. REGISTRATION #______________________________________________________ FEDERAL TAX I.D. #______________________________________ CITY OF VISALIA BUSINESS TAX CERTIFICATE #__________________________________(A City Business Tax Certificate (license) is not required to submit a bid; however, vendor is required to obtain a City License prior to commencement of work or if vendor is presently transacting business within the City of Visalia, regardless of whether the business address is actually located within the City. Contact the business License Division for clarification of questions at 559-713-4326.
CONTRACTOR’S REFERENCES: The following are the names, addresses, and telephone numbers for at least three (3) agencies for which BIDDER has performed work similar in size and scope within the past two (2) years.
REFERENCE 1
NAME OF AGENCY:__________________________________________________CONTACT PERSON:_____________________ AGENCY ADDRESS:_________________________________________________PHONE #:_______________________________ REFERENCE 2
NAME OF AGENCY:__________________________________________________CONTACT PERSON:____________________ AGENCY ADDRESS:_________________________________________________PHONE #:_______________________________ REFERENCE 3
NAME OF AGENCY:__________________________________________________CONTACT PERSON:_____________________ AGENCY ADDRESS:_________________________________________________PHONE #:_______________________________
DESIGNATION OF SURETIES
The following are the names, addresses, and telephone numbers for all brokers and sureties from whom BIDDER intends to procure insurance.
COMPANY NAME:_______________________________________________TYPE OF INSURANCE:_______________________ ADDRESS:_____________________________________________TELEPHONE#_______________________________ COMPANY NAME:_______________________________________________TYPE OF INSURANCE:_______________________ ADDRESS:_____________________________________________TELEPHONE#_______________________________ COMPANY NAME:_______________________________________________TYPE OF INSURANCE:_______________________ ADDRESS:_____________________________________________TELEPHONE#_______________________________ 936
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
SUBCONTRACTOR LISTING BIDDING AGENCY:____________________________ The undersigned hereby designates below for the project, opposite various portions of the work, the names and locations of the places of business of each subcontractor who will perform work or labor in an amount in excess of one-half of one percent (1/2 of 1%) of the of the total bid. All work not listed below shall be performed by the undersigned BIDDER. It is understood that the BIDDER, if awarded the contract, shall not substitute any subcontractor in place of the subcontractors herein designated without the approval of the Project Manager.
SUBCONTRACTOR INFORAMTION & TRADE CLASSIFICATION (CIRCLE ALL THAT APPLY)
1. Subcontractor
Name:
Performing
_____% of
project
work
Asbestos
Boilermaker
Bricklayers
Carpenters
Carpet/Linoleum
Cement Mason
Drywall Finisher
Drywall/Lathers
Electricians
Elevator
Mechanic
Glaziers
Iron Worker
Laborers
Millwrights
Operating
Engineers
Painters
Pile Drivers
Pipe Trades
Plasterers
Roofers
Sheet Metal
Sound/Comm
Surveyors
Teamster
Tile Worker
Other: ________
Business Address:
Email Address:
CSLB # Expires:
DIR Registration #
2. Subcontractor
Name:
Performing
_____% of
project
work
Asbestos
Boilermaker
Bricklayers
Carpenters
Carpet/Linoleum
Cement Mason
Drywall Finisher
Drywall/Lathers
Electricians
Elevator
Mechanic
Glaziers
Iron Worker
Laborers
Millwrights
Operating
Engineers
Painters
Pile Drivers
Pipe Trades
Plasterers
Roofers
Sheet Metal
Sound/Comm
Surveyors
Teamster
Tile Worker
Other: ________
Business Address:
Email Address:
CSLB # Expires:
DIR Registration #
3. Subcontractor
Name:
Performing
_____% of
project
work
Asbestos
Boilermaker
Bricklayers
Carpenters
Carpet/Linoleum
Cement Mason
Drywall Finisher
Drywall/Lathers
Electricians
Elevator
Mechanic
Glaziers
Iron Worker
Laborers
Millwrights
Operating
Engineers
Painters
Pile Drivers
Pipe Trades
Plasterers
Roofers
Sheet Metal
Sound/Comm
Surveyors
Teamster
Tile Worker
Other: ________
Business Address:
Email Address:
CSLB # Expires:
DIR Registration #
* Note: If more space is needed to list additional subcontractor and trade classifications, please list remaining subcontractors on a separate sheet of paper and submit with Bid. 937
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
EXHIBIT “B-1”
Submit with Bid
BID GUARANTEE
Known all men by these presents:
That we, ____________________________ ________________ as principal and __________________________________________________ as surety, are held and firmly bound unto the City of Visalia (obligee) in the sum of ten percent (10%) of the total amount of the bid of the principal, to be paid to the said City or its certain attorney, its successors and assigns, for which payment well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors or assigns, jointly and severally, firmly by these presented.
In no case shall the liability of the surety hereunder exceed the sum of $____________________.
THE CONDITION OF THIS OBLIGATION IS SUCH, that whereas the principal has submitted the above mentioned bid to the City of Visalia for certain construction specifically described as follows, for which bids are to be opened at ___________________________ on ___________________________________ for improvement of Invitation to Bid No. 25-26-16
Project: Biofilter Media Replacement & Associated Equipment Inspection at Visalia Water Reclamation Facility
NOW THEREFORE, if the aforesaid principal is awarded the contract, and within the time and manner required under the specifications, after the prescribed form in accordance with the bid, and files the two bonds with the City of Visalia, one to guarantee faithful performance and the other to guarantee payment of labor and materials, as required by law, then this obligation shall be null and void, otherwise it shall be and remain in full force and effect.
In the event suit is brought upon this bond by the obligee and judgment is recovered, the surety shall pay all costs incurred by the obligee in such suit, including a reasonable attorney’s fee to be fixed by the court.
IN WITNESS WHEREOF, we have hereunto set our hands and seals on this _______________________________ day of _______________________________, 2026
Company (Principal): ______________________________________________ Business Address: ______________________________________________ Signature:_______________________________________________________________ ___ Date:________________________ Name of Signing Official: _____________________________________________________ Title:_________________________ Company Seal (if any):
Company (Surety): ______________________________________________ Business Address: ______________________________________________ Signature:_______________________________________________________________ ___ Date:________________________ Name of Signing Official: _____________________________________________________ Title:_________________________
Company Seal (if any):
Note: Signatures of those executing for the surety must be properly acknowledged. 938
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
EXHIBIT “B-2”
Submit with Bid
NON-COLLUSION AFFIDAVIT
(Title 23 United States Code Section 112 and Public Contract Code Section 7106) In accordance with Title 23 United States Code section 112 and Public Contract Code 7106 the bidder declares that bid is not made in the interest of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price of the bidder or any other bidder, or to fix any overhead, profit, or cost element of the bid price, or of that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay, any fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. __________________________________________ ________________________ Signature Date
Note: The above Non-collusion Affidavit is part of the Bid/Proposal.
Bidders are cautioned that making a false certification may subject the certifier to criminal prosecution.
939
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
EXHIBIT “B-3”
Submit with Bid
WORKERS’ COMPENSATION INSURANCE CERTIFICATE
(CALIF. LABOR CODE § 3700)
STATE OF CALIFORNIA )
) ss
CITY OF VISALIA )
I am aware of the provisions of Section 3700 of the Labor Code which requires every employer to be insured against liability for workers’ compensation or to undertake self-insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work under this contract.
Company: ______________________________________________ Business Address: ______________________________________________ Signature: ______________________________________________ Name of Signing Official: ______________________________________________ Title of Signing Official: ______________________________________________ Date: ______________________________________________
Company Seal (if any):
940
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
EXHIBIT “B-4”
Submit with Bid
EQUAL EMPLOYMENT OPPORTUNITY COMPLIANCE CERTIFICATE
(EXECUTIVE ORDER 11246)
Equal Opportunity Clause
Unless exempted by rules, regulations or orders of the Secretary of Labor issued pursuant to Executive Orders 10925, 11114 or Section 204 of Executive Order 11246 of September 24, 1965, during the performance of each contract with the City of Visalia, the BIDDER agrees as follows:
1. The BIDDER will not discriminate against any employee or applicant for employment because of race, color, religion, gender, national origin or political affiliation. The BIDDER will take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, gender, national origin or political affiliation. Such action shall include, but not be limited to, the following:
employment upgrading, demotion or transfer, recruitment or recruitment advertising, layoff or termination, rates of pay or other forms of compensation, and selection for training, including apprenticeship. The BIDDER agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the contracting officer setting forth the provisions of this nondiscrimination clause.
2. The BIDDER will, in all solicitations or advertisements for employees, placed by or on behalf of the BIDDER, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, gender, national origin or political affiliation.
3. The BIDDER will send to each labor union or representative of workers with which he has a collective bargaining agreement or other contract or understanding, a notice to be provided by the agency contracting officer, advising the labor union or the workers’ representative of the BIDDER’s commitments under Section 202 of Executive Order 11246 of September 24, 1965, and shall post copies of the notice on conspicuous places available to employees and applicants for employment.
4. The BIDDER will comply with all provisions of Executive Order 11246 of September 24, 1965, and the rules, regulations and relevancy orders of the Secretary of Labor.
5. The BIDDER will furnish all information and reports required by Executive Order 11246 of September 24, 1965, and by the rules, regulations and relevant orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records and accounts by the contracting agency and the Secretary of Labor for purposes of investigation to ascertain compliance with such rules, regulations and orders.
6. In the event of the BIDDER’s non-compliance with the non-discrimination clauses of this subcontract or with any of such rules, regulations or orders, this subcontract may be canceled, terminated or suspended, in whole, or in part and the BIDDER may be declared ineligible for further government contracts in accordance with the procedures authorized in accordance with Executive Order 11246 of September 24, 1965, and such other sanctions may be imposed and remedies invoked as provided in Executive Order 11246 of September 24, 1965, or by rule, regulation or order of the Secretary of Labor, or otherwise provided by law.
7. The BIDDER will include the provisions of Paragraphs (1) through (7) in every subcontract or purchase order unless exempted by rules, regulations or orders of the Secretary of Labor issued pursuant to Section 204 of Executive Order 11246 of September 24, 1965, so that such provisions will be binding upon each SUBBIDDER or vendor. The BIDDER will take such action with respect to any subcontract or purchase order as the contracting agency may direct as a means of enforcing such provisions including sanctions for non-compliance. Provided, however, that in the event the BIDDER becomes involved in, or is threatened with litigation with a SUBBIDDER or vendor as a result of such direction by the contracting agency, the BIDDER may request the United States to enter into such litigation to protect the interest of the United States.
Company: ______________________________________________ Business Address: ______________________________________________ Signature:______________________________________________ Date:________________ Name & Title of Signing Official: ______________________________________________ Company Seal (if any)
Note: Executive Order 11246 has been rescinded effective January 2025. 941
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
EXHIBIT “B-5”
Submit with Bid
OWNERSHIP DISCLOSURE AND CALIFORNIA LEVINE ACT STATEMENT The following disclosure and statement apply to the Bidder/Proposer/Contractor/Consultant/ Vendor/Supplier or Company:
1. submitting a bid or proposal in response to a solicitation by City of Visalia; or
2. as Awardee of a contract/purchase order which is subject to approval by the Visalia City Council.
OWNERSHIP DISCLOSURE
_________________________________________________________________________________________________________ Name of Bidder/Proposer/Contractor/Consultant/Vendor/Supplier or Company _________________________________________________________________________________________________________ Address
List the names of all principals, partners, and/or trustees. For corporations, provide names of officers, directors and all stockholders owning more than 10% equity interest in corporation:
___________________________________________________________________________________________________________ ___________________________________________________________________________________________________________ ___________________________________________________________________________________________________________
CALIFORNIA LEVINE ACT STATEMENT
California Government Code Section 84308, also know as the “Levine Act,” can prohibit members of the Visalia City Council from participating in any action related to a contract if he or she receives any political contributions totaling more than $500 within the previous twelve (12) months, and for twelve (12) months following the date a final decision concerning the contract has been made, from the person or company awarded the contract. The Levine Act also requires disclosure of such contribution(s) by a party to be awarded a specific contract.
The following website contains a list of current Visalia City Council Members, https://www.visalia.city/government/city_council/default.asp. You are responsible for reviewing the names of Visalia City Council Members prior to making the following disclosure:
1. Have you or your company, or any agent on behalf of you or your company, made any political contributions of more than $500 to a Visalia City Council Member in the twelve (12) months preceding the date of the submission of your proposals or the anticipated date of any City Council action related to this contract?
YES:_____ NO:_____. If yes, please identify the City Council Member(s) and date(s) of contribution in the space below:
Council Member(s) Name Date of Contribution(s)
_____________________________ ___________________________ Answering YES, does not preclude the City of Visalia from awarding a contract to your firm or from taking any subsequent action related to the contract. It does, however, preclude the identified Visalia City Council Member(s) from participating in any actions related to this contract.
NOTICE: The disclosure duty under state law continues for twelve (12) months after the award. If the above information regarding contributions changes during this time after the award, then the awardee is required to update this disclosure form.
_____________________________________________________________________________________________ Print or Type Name of Bidder/Proposer/Contractor/Consultant/Supplier/Vendor/Company
Signature of Company Authorized Individual Print or Type Name of Authorized Individual Date 942
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
EXHIBIT “B-6”
Submit with Bid
STATE OF CALIFORNIA
DRUG-FREE WORKPLACE CERTIFICATION
STD.21 (REV.12-93)
I, the official named below, hereby swear that I am duly authorized legally to bind the contractor or grant recipient to the certification described below. I am fully aware that this certification, executed on the date below, is made under penalty of perjury under the laws of the State of California.
CONTRACTOR/BIDDER FIRM NAME FEDERAL ID NUMBER
BY(Authorized Signature) DATE EXECUTED
PRINTED NAME OF PERSON SIGNING TELEPHONE NUMBER (Include Area Code) ( )
TITLE
CONTRACTOR/BIDDER FIRM’S MAILING ADDRESS
The contractor or grant recipient named above hereby certifies compliance with Government Code Section 8355 in matters relating to providing a drug-free workplace. The above-named contractor or grant recipient will:
1. Publish a statement notifying employees that unlawful manufacture, distribution, dispensation, possession, or use of a controlled substance is prohibited and specifying actions to be taken against employees for violations, as required by Government Code Section 8355(a).
2. Establish a Drug-Free Awareness Program as required by Government Code Section 8355(b), to inform employees about all of the following:
(a) The dangers of drug abuse in the workplace,
(b) The person’s or organization’s policy of maintaining a drug-free workplace, (c) Any available counseling, rehabilitation and employee assistance programs, and (d) Penalties that may be imposed upon employees for drug abuse violations.
3. Provide as required by Government Code Section 8355©, that every employee who works on the proposed contract or grant:
(a) Will receive a copy of the company’s drug-free workplace policy statement, and (b) Will agree to abide by the terms of the company’s statement as a condition of employment on the contract or grant.
4. At the election of the contractor or grantee, from and after the “Date Executed” and until ____________ (NOT TO EXCEED 36 MONTHS), the state will regard this certificate as valid for all contracts or grants entered into between the contractor or grantee and this state agency without requiring the contractor or grantee to provide a new and individual certificate for each contract or grant. If the contractor or grantee elects to fill in the blank date, than the terms and conditions of this certificate shall have the same force, meaning effect and enforceability as if a certificate were separately, specifically, and individually provided for each contract or grant between the contractor or grantee and this state agency. 943
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
EXHIBIT “B-7”
Submit with Bid
AMERICANS WITH DISABILITIES ACT COMPLIANCE CERTIFICATE
By submission of a bid, the BIDDER certifies it will comply with the Americans with Disabilities Act, 42 U.S.C., 12101 et. seq., and will maintain compliance throughout the life of this Contract.
By commencing performance of the Contract work, the selected BIDDER certifies to the Americans with Disabilities Act compliance.
Company: ______________________________________________ Business Address: ______________________________________________ Signature: ______________________________________________ Name of Signing Official: ______________________________________________ Title of Signing Official: ______________________________________________ Date: ______________________________________________
Company Seal (if any):
944
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
EXHIBIT “B-8”
Submit with Bid
IRAN CONTRACTING ACT CERTIFICATION
(Public Contract Code Section 2200 et seq.)
As required by California Public Contract Code Section 2204, the Contractor certifies subject to penalty for perjury that the option checked below relating to the Contractor’s status in regard to the Iran Contracting Act of 2010 (Public Contract Code Section 2200 et seq.) is true and correct:
⃝ The Contractor is not:
(1) Identified on the current list of persons and entities engaged in investment activities in Iran prepared by the California Department of General Services in accordance with subdivision (b) of Public Contract Code Section 2203; or (2) A financial institution that extends, for 45 days or more, credit in the amount of $20,000,000 or more to any other person or entity identified on the current list of persons and entities engaging in investment activities in Iran prepared by the California Department of General Services in accordance with subdivision (b) of Public Contract Code Section 2203, if that person or entity uses or will use the credit to provide goods or services in the energy sector in Iran. ⃝ The City has exempted the Contractor from the requirements of the Iran Contracting Act of 2010 after making a public finding that, absent the exemption, the City will be unable to obtain the goods and/or services to be provided pursuant to the Contract. ⃝ The amount of the Contract payable to the Contractor for the Project does not exceed $1,000,000 over the life of the contract (up to 5 years).
Signature:________________________________ Printed Name:_______________________ Title:____________________________________ Agency Name:_________________________ Date:____________________
Note: In accordance with Public Contract Code Section 2205, false certification of this form shall be reported to the California Attorney General and may result in civil penalties equal to the greater of $250,000 or twice the Contract amount, termination of the Contract and/or eligibility to bid on contracts for three years.
945
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
EXHIBIT “B-9”
Submit with Bid
CERTIFICATE OF NONSEGREGATED FACILITIES
(BIDDERS/SUBCONTRACTORS)
1. “Segregated facilities,” as used in this provision, means any waiting rooms, work areas, rest rooms and wash rooms, restaurants and other eating areas, time clocks, locker rooms and other storage or dressing areas, parking lots, drinking fountains, recreation or entertainment areas, transportation, and housing facilities provided for employees, that are segregated by explicit directive or are in fact segregated on the basis of race, color, religion, or national origin, because of habit, local custom, or otherwise.
2. By the submission of a bid, the BIDDER certifies that it does not and will not maintain or provide for its employees any segregated facilities at any of its establishments, and that it does not and will not permit its employees to perform their services at any location under its control where segregated facilities are maintained. The BIDDER agrees that a breach of this certification is a violation of the Equal Opportunity clause in the contract.
3. By submission of the bid, the BIDDER further agrees that (except where it has obtained identical certifications from proposed SUBCONTRACTORs for specific time periods) it will:
(a) Obtain identical certifications from proposed SUBCONTRACTORs before the award of subcontracts under which the SUB-BIDDER will be subject to the Equal Opportunity clause;
(b) Retain such certifications in its files; and
(c) Forward this certification and the following notice to the proposed SUBCONTRACTORs:
NOTICE OF PROSPECTIVE SUBCONTRACTORS OF REQUIREMENT
FOR CERTIFICATION OF NONSEGREGATED FACILITIES
A certificate of Nonsegregated Facilities must be submitted before the award of a subcontract under which the SUBCONTRACTOR will be subject to the equal Opportunity clause. The certification may be submitted either for each SUBCONTRACTOR for all subcontracts during a period (i.e., quarterly, semi-annually, or annually).
4. By commencing performance of the Contract work, the selected BIDDER certifies to the Nonsegregated Facilities provisions above.
Company: ______________________________________________ Business Address: ______________________________________________ Signature: ______________________________________________ Name of Signing Official:______________________________________________ Date:__________ Title of Signing Official:______________________________________________ Company Seal (if any):
946
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
EXHIBIT “B-10”
Submit with Bid
CERTIFICATION OF ANTI-KICKBACK COMPLIANCE
(48 Stat. 948; 62 Stat. 740; 63 Stat. 108; Title 18 U.S.C. § 8741; and 40 U.S.C. (c)) By submission of a Bid, the BIDDER certifies that it has read the “Anti-Kickback Procedures,” referenced above and that neither it nor any of its employees has performed or participated in any prohibited actions, as defined in that provision, relating to the award of the Contract. By commencing performance of the Contract work, the selected BIDDER certifies to Anti-Kickback Compliance.
Company: _____________________________________________
Business Address: _____________________________________________ Signature: _____________________________________________ Name of Signing Official: __________________________________________ Title of Signing Official:____________________________________________ Date: _____________________________________________
Company Seal (if any):
947
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
EXHIBIT “B-11”
Submit with Bid
CLEAN AIR ACT AND WATER POLLUTION CONTROL CERTIFICATION CLEAN AIR ACT 42 U.S.C. § 7401-7671q.) and the FEDERAL WATER POLLUTION CONTROL ACT as amended
(33 U.S.C. § 1251-1387). 49 CFR, Part 18, Section 18.36) BIDDER agrees that any facility to be used in the performance of the contract, or to benefit from the contract, is not listed on the Environmental Protection Agency List of Violating Facilities.
BIDDER also agrees to comply with all the requirements of Section 114 of the Clean Air Act, as amended, 42 U.S.C. 1857 et seq. and Section 308 of the Federal Water Pollution Control Act, as amended 33 U.S.C. 1251 et seq. relating to the inspection, monitoring, entry, reports and information, as well as all other requirements specified in Section 114 and Section 308 of the Acts, respectively, and all other regulations and guidelines issued thereunder.
BIDDER agrees that as a condition for award of the contract, the BIDDER will notify the awarding official of the receipt of any communication from the EPA indicating that a facility to be used for the performance of, or benefit from, the contract is under consideration to be listed on the EPA List of Violating Facilities.
Company: ______________________________________________ Business Address: ______________________________________________ Signature: ______________________________________________ Name of Signing Official: ______________________________________________ Title of Signing Official: ______________________________________________ Date: ______________________________________________
Company Seal (if any):
948
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
EXHIBIT “C”
SAMPLE PROJECT AGREEMENT
BIOFILTER MEDIA REPLACEMENT & ASSOCIATED EQUIPMENT INSPECTION AT THE
WATER RECLAMATION FACILITY
(City of Visalia Bid No. 25-26-16)
This Agreement, entered into and effective this ________ day of ________________, 2026 [“Effective Date”], by and between the City of Visalia, hereinafter referred to as the “CITY”, and ____________________________ hereinafter referred to as the “CONTRACTOR”, “BIDDER”, or “SUBRECIPIENT”.
R E C I T A L S
WHEREAS, CONTRACTOR is an ____________________ (insert individual or entity type) with a primary business address of ____________________ and SSN or EIN: ____________________; and WHEREAS, CITY is a municipal corporation and Charter Law City; and WHEREAS, CITY desires completion of the Biofilter Media Replacement & Associated Equipment Inspection Project, which was let to bid on ___________ as evidenced by Bid No. 25-26-16 (the “Project”); and
WHEREAS, City of Visalia reviewed and evaluated responses to the Bid and determined to award a contract to CONTRACTOR for the Project; and
WHEREAS, CONTRACTOR represents it is licensed, qualified and willing to complete the Project pursuant to terms and conditions of this Agreement.
NOW, THEREFORE, CITY and CONTRACTOR agree as follows:
1. TERM:
The term of this Agreement shall commence on the Effective Date and expire upon completion of all obligations of the parties, unless earlier terminated by the parties. The indemnification and defense provisions shall survive expiration and termination. Suspension or termination of this Agreement may occur if CONTRACTOR materially fails to comply with any term of the award. Additionally, this Agreement may be terminated for convenience. In the event of termination or expiration of this Agreement, CONTRACTOR shall transfer to CITY any funds and/or accounts receivable on hand attributable to the use of CITY funds.
2. ATTACHMENTS INCORPORATED:
The following are attachments for this Agreement. Said attachments are incorporated into this Agreement as if included in full in the body:
ATTACHMENT NO. DESCRIPTION OF ATTACHMENT
Attachment 1 General Contract Provisions
Attachment 2 Insurance Requirements
Attachment 3 City of Visalia Bid 25-26-16 Biofilter Media Replacement & Associated Equipment Inspection
Attachment 4 CONTRACTOR’s bid in response to Bid No. 25-26-16
3. CONTRACTOR SCOPE OF SERVICES and COMMITMENTS*:
CONTRACTOR shall provide the following services for the stated compensation on or before the stated completion dates (“Scope of Services”):
949
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
All work described in Scope of Services in Bid No. 25-26-16
4. CITY COMMITMENTS:
CITY shall perform the following tasks on or before the stated completion dates:
TASK COMPLETION DATE
Pay Contractor as work is completed and invoiced As requested by Contractor
5. COMPENSATION:
CITY shall pay CONTRACTOR compensation for services as indicated in Paragraph 4 above; however, CITY shall pay not more than the following amount as total compensation under this Agreement, unless otherwise agreed in writing. Such sum shall be expended and paid by CITY on a reimbursement basis for services actually performed based on invoices, receipts, time sheets and similar documents presented by CONTRACTOR to CITY. *CONTRACTOR may elect to avoid the 5% retention by depositing securities of equivalent value pursuant to California Public Contract Code Section 22300.
IN WITNESS WHEREOF, this Agreement is executed on the day and year first above written.
CONTRACTOR
Dated: ___________________ By:______________________________________________________ Authorized Officer: I certify under penalty of perjury under the laws of the State of California that I am fully authorized to execute this Agreement for CONTRACTOR in the capacity I have stated, and that such execution is sufficient to bind the CONTRACTOR.
CITY OF VISALIA
Dated: ____________________ By:______________________________________________________ City Manager
Dated: ____________________ By:______________________________________________________ City Attorney
Dated: ____________________ By:______________________________________________________ City of Visalia Risk Manager
Dated: ____________________ By:______________________________________________________ City of Visalia Project Manager
Total Compensation: $
Source of Funds: Local Revenues
Payment Schedule: Within 30 days from receipt of approved invoice for completed work, less 5% retention until 35 days after work is completed and accepted by CITY as evidenced by the recordation of a Notice of Completion*
950
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
Exhibit “C”
Attachment 1
GENERAL CONTRACT PROVISIONS
A. Successors and Assigns: This Agreement shall be binding upon and shall inure to the benefit of any successors to or assigns of the parties.
B. Prohibition of Assignment: Neither party shall assign, delegate or transfer their rights and duties in this Agreement without the written consent of the other party.
C. Notices: Notice shall be sufficient hereunder if personally served upon the City Clerk of the CITY or an officer or principal of the CONTRACTOR, or if sent via the United States Postal Service, postage prepaid, addressed as follows:
CITY OF VISALIA CONTRACTOR
707 W. Acequia Ave. _______________________
Visalia, CA 93291 _______________________
Attention: City Clerk Attention: _____________
D. Independent Contractor: It is understood and agreed by the parties herein that CONTRACTOR, in the performance of this Agreement, shall act as an independent contractor, and therefore shall obtain no rights to any fringe benefits that accrue to regular full-time CITY employees.
E. Jurisdiction/Venue/Waiver Of Removal: This Agreement shall be administered and interpreted under the laws of the State of California. Jurisdiction of litigation arising from this Agreement shall be in California. Any action brought to interpret or enforce this Agreement, or any of the terms or conditions hereof, shall be brought in Tulare County, California. The CONTRACTOR hereby expressly waives any right to remove any action to a county other than Tulare County as permitted pursuant to Section 394 of the California Code of Civil Procedure.
F. Integration/Modification: This Agreement and each of the documents and exhibits or attachments referenced herein, which are incorporated by reference, represents the entire understanding of the parties as to those matters contained herein. No prior oral or written understanding shall be of any force or effect with respect to those matters covered hereunder. This Agreement may not be modified or altered except in writing signed by the parties, unless otherwise explicitly authorized.
G. Conflict With Law: If any part of this Agreement is found to be in conflict with applicable laws, such part shall be inoperative, null and void insofar as it is in conflict with said law, but the remainder of the Agreement shall be in full force and effect.
H. Indemnification: The CONTRACTOR waives any and all claims and recourse against the CITY, including the right of contribution of loss or damage to person or property arising from, growing out of, or in any way connected with or incidental to the CONTRACTOR’s performance of this Agreement, except claims arising from the concurrent or sole negligence of the CITY or its officers, agents or employees. The CONTRACTOR will indemnify, hold harmless, and defend (at CITY’s option) the CITY against any and all claims, demands, damages, costs, expenses, or liability arising out of the CONTRACTOR’s performance of this Agreement except for liability arising out of the concurrent or sole negligence of the CITY or its officers, agents, or employees.
I. Guarantees and Warranties:
1. IN GENERAL: All guarantees and warranties specifically called for by the specifications and/or this Agreement shall expressly run to the benefit of the CITY. 951
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
2. ONE YEAR GUARANTEE: Besides guarantees required elsewhere, CONTRACTOR shall and hereby does guarantee the project work for a period of one year after the date of acceptance by CITY.
3. WARRANTIES: Warranties required by the Invitation to Bid or this Agreement shall commence on the date of acceptance of the work by CITY, unless otherwise provided in a Certificate of Substantial Completion.
CONTRACTOR warrants that the materials and equipment furnished under the Agreement will be new and of recent manufacturer unless otherwise specified, and that all work will be of good quality, free from faults and defects, and in conformance with the Agreement. Work that does not conform may be considered defective. This warranty excludes remedy for damage or defect caused by abuse, modifications not executed by the CONTRACTOR, improper or insufficient maintenance, improper operation, or normal wear and tear under normal usage.
CONTRACTOR warrants that title to all work covered by an application for payment will pass to the CITY either by incorporation in the construction or upon the receipt of payment by the CONTRACTOR, whichever occurs first, free and clear of all liens.
CONTRACTOR warrants and guarantees that title to all work, materials, and equipment covered by any application for payment, whether incorporated in the project or not, will pass to CITY no later than the time of payment free and clear of all liens.
No materials or supplies for the project shall be purchased by the CONTRACTOR or SUBCONTRACTOR subject to any mortgage or under a condition of sale contract or other agreement by which an interest is retained by the seller. CONTRACTOR warrants that it has good title to all materials and supplies used by it in the project, free from all liens.
CONTRACTOR shall indemnify and hold CITY harmless from all claims growing out of the lawful demands of SUBCONTRACTORS, laborers, workers, mechanics, material persons, and furnishers of machinery and parts thereof, equipment, power tools, and all supplies, incurred in furtherance of the performance of this Agreement. CONTRACTOR shall, at CITY’s request, furnish satisfactory evidence that all obligations of the nature here and above designated have been paid, discharged, or waived. If CONTRACTOR fails to do so, then CITY may, after having served written notice on the CONTRACTOR, either pay directly unpaid bills, of which the CITY has written notice, or withhold from the CONTRACTOR’s unpaid compensation a sum of money deemed reasonably sufficient to pay any and all such lawful claims until satisfactory evidence is furnished that all liabilities have been fully discharged where upon payment to the CONTRACTOR shall be resumed, in accordance of the terms of this Agreement, but in no event shall the provisions of this sentence be construed to impose any obligations on the CITY to either the CONTRACTOR or its surety. In paying any unpaid bills of the CONTRACTOR, the CITY shall be deemed the agent of the CONTRACTOR and any payment so made by the CITY shall be considered as payment made under the contract by the CITY to the CONTRACTOR and the CITY shall not be liable to the CONTRACTOR for any such payments made in good faith.
Any defective work that is either corrected or replaced shall be warrantied and guaranteed for a period of one year from the date of such correction or replacement.
J. Attorney’s Fees: In the event either party commences any action, arbitration or legal proceedings for the enforcement of this Agreement, the prevailing party, as determined by the court or arbitrator, shall be entitled to recovery of its attorney’s fees and court costs incurred in the action brought thereon.
K. Headings: Section headings are provided for organizational purposes only and do not in any manner affect the scope or intent of the provisions thereunder. 952
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
L. Firearms Prohibited: Guns may not be carried by contractors /vendors/consultants while working on City of Visalia premises without the expressed written approval of a City of Visalia Department Head, or an exemption in the contract. If a contractor/vendor/ consultant is caught carrying a gun, without City permission, their contract will be terminated.
M. Executive Order N-6-22 – Russia Sanctions
On March 4, 2022, Governor Gavin Newsom issued Executive Order N-6-22 (the EO) regarding Economic Sanctions against Russia and Russian entities and individuals. “Economic Sanctions” refers to sanctions imposed by the U.S. government in response to Russia’s actions in Ukraine, as well as any sanctions imposed under state law. The EO directs state agencies to terminate contracts with, and to refrain from entering any new contracts with, individuals or entities that are determined to be a target of Economic Sanctions. Accordingly, should the State determine Contractor is a target of Economic Sanctions or is conducting prohibited transactions with sanctioned individuals or entities, that shall be grounds for termination of this agreement. The State shall provide Contractor advance written notice of such termination, allowing Contractor at least 30 calendar days to provide a written response. Termination shall be at the sole discretion of the State.
N. Time is of the Essence: Time is of the essence in the performance of the construction anticipated by this Contract.
O. Liquidated Damages: CITY AND CONTRACTOR ACKNOWLEDGE AND AGREE THAT TIME IS OF THE ESSENCE FOR THIS PROJECT. THEREFORE, FOR EACH DAY THE
PROJECT IS DELAYED BEYOND THE AGREED COMPLETION DATE OF ONE HUNDRED TWENTY (120) CALENDAR DAYS, IT WOULD BE EXTREMELY DIFFICULT AND IMPRACTICAL TO ASCERTAIN THE EXTENT OF THE DETRIMENT TO CITY. THE PARTIES
HAVE DETERMINED AND AGREED THAT THE ACTUAL AMOUNT OF DAMAGES THAT
WOULD BE SUFFERED BY CITY AS A RESULT OF ANY SUCH DELAY IS THE SUM OF SEVEN HUNDRED FIFTY DOLLARS ($750.00) PER DAY, WHICH IS A REASONABLE ESTIMATE OF THE AMOUNT OF SUCH DAMAGES. THE PAYMENT OF SUCH AMOUNT
AS LIQUIDATED DAMAGES IS NOT INTENDED AS A FORFEITURE OR PENALTY WITHIN THE MEANING OF CALIFORNIA CIVIL CODE SECTIONS 3275 OR 3369, BUT IS
INTENDED TO CONSTITUTE LIQUIDATED DAMAGES TO CITY PURSUANT TO CALIFORNIA CIVIL CODE SECTIONS 1671, 1676 AND 1677. CITY HEREBY WAIVES THE PROVISIONS OF CALIFORNIA CIVIL CODE SECTION 3389. CITY AGREES THAT THESE
LIQUIDATED DAMAGES SHALL BE IN LIEU OF ANY OTHER MONETARY RELIEF OR
OTHER REMEDY FOR DELAY, INCLUDING, WITHOUT LIMITATION, SPECIFIC
PERFORMANCE, TO WHICH CITY MIGHT OTHERWISE BE ENTITLED UNDER THIS AGREEMENT, AT LAW OR IN EQUITY, AND SHALL BE CITY’s SOLE AND EXCLUSIVE RIGHT AND REMEDY, EXCEPT THAT CITY MAY TERMINATE THE AGREEMENT.
CITY CONTRACTOR ________
953
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
Exhibit “C”
Attachment 2
INSURANCE REQUIREMENTS
1. CONTRACTOR Insurance. CONTRACTOR, at its sole cost and expense, for the full term of this Agreement (and any extensions thereof), shall obtain and maintain at a minimum compliance with all of the following insurance coverage(s) and requirements. Such insurance coverage shall be primary coverage as respects CITY and any insurance or self-insurance maintained by CITY shall be in excess of CONTRACTOR’s insurance coverage and shall not contribute to it.
2. Subcontractor(s’) Insurance. If CONTRACTOR utilizes one or more subcontractors in the performance of this Agreement, CONTRACTOR shall obtain and maintain independent insurance as to each subcontractor or otherwise provide evidence of insurance coverage for each subcontractor equivalent to that required of CONTRACTOR in this Agreement.
3. Types of Insurance and Minimum Limits. The following types of insurance and minimum limits are required providing at least the following minimum coverage and limits of liability:
a. Worker’s Compensation written in accordance with the laws of the State of California providing coverage for any and all employees of CONTRACTOR in the minimum statutorily required coverage amounts;
b. Automobile Liability Insurance for each of CONTRACTOR’s vehicles used in the performance of this Agreement, including owned, non-owned (e.g. owned by CONTRACTOR’s employees or contractors), leased or hired vehicles, in the minimum amount of $1,000,000 combined single limit per occurrence for bodily injury and property damage.
c. Professional Liability insurance coverage, in an amount not less than One Million Dollars ($1,000,000).
d. Comprehensive or Commercial General Liability Insurance coverage in the minimum amount of $1,000,000 combined single limit, including coverage for:
(1) bodily injury;
(2) personal injury;
(3) broad form property damage;
(4) contractual liability;
(5) cross-liability;
(6) products and completed operations liability
4. Other Insurance Provisions.
If any insurance coverage required in this Agreement is provided on a “Claims Made” rather than “Occurrence” form, CONTRACTOR agrees to maintain the required coverage for a period of three (3) years after the expiration of this Agreement (hereinafter “post agreement coverage”) and any extensions thereof. CONTRACTOR may maintain the required post agreement coverage by renewal or purchase of prior acts or tail coverage.
This provision is contingent upon post agreement coverage being both available and reasonably affordable in relation to the coverage provided during the term of this Agreement. For purposes of interpreting this requirement, a cost not exceeding 100% of the last annual policy premium during the term of this Agreement in order to purchase prior acts or tail coverage for post agreement coverage shall be deemed to be reasonable.
5. Endorsements.
All required Automobile and Comprehensive or Commercial General Liability Insurance shall be endorsed to contain the following clauses:
954
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
a. The City of Visalia, its officers, agents, employees, representatives, and volunteers are added as additional insureds as respects operations and activities of, or on behalf of the named insured, performed under contract with the City of Visalia. b. It is agreed that any insurance maintained by the City of Visalia shall apply in excess of and not contribute with insurance provided by this policy. c. This insurance shall not be canceled, limited in scope or coverage, or non-renewed until after thirty (30) days prior written notice has been given to the City Clerk, City of Visalia, 707 W. Acequia, Visalia, CA, 93291
6. Proof of Coverage.
CONTRACTOR agrees to provide its insurance broker(s) with a full copy of these insurance provisions and provide CITY on or before the effective date of this Agreement with Certificate(s) of Insurance for all required coverages. Copies of all the required Endorsements shall be attached to the Certificate(s) of Insurance or other evidence of insurance acceptable to the City of Visalia, which shall be provided by CONTRACTOR’s insurance company as evidence of the stipulated coverages. This Proof of Coverage shall then be mailed to the City of Visalia at the following address:
City of Visalia
707 W. Acequia
Visalia, CA 93291
Attn: Purchasing Division
955
RFB NO. 25-26-16
Biofilter Media Replacement & Associated Equipment Inspection
Exhibit “D”
SAMPLE CONTRACTOR AFFIDAVIT
I, declare under penalty of perjury
(Affidavit’s Name)
under the laws of the State of California and the provisions of the California Labor Code §1771, §1773.1, §1775, §1776, §1777.5, §1813 and §1815 that:
1. I am the of and I
(Officer, Owner, Partner) (Company)
am responsible for the payment of persons employed by
(Company)
who performed work on the City of Visalia Project entitled:
2. During all payroll periods from through ,
(first work date) (last work date)
All persons employed by on this project
(Company)
have at all times been paid, at a minimum, the specified general prevailing rate of per diem wages and any amounts due.
3. During all payroll periods on this project, all apprenticeship requirements have been complied with.
Executed and sworn to this day of ,
(Day) (Month) (Year)
___________________________________ __________________
(Signature) (Date)
956
Visalia WRF O&M Manual
CHAPTER 15: ODOR CONTROL SYSTEM
15.1 INTRODUCTION
15.2 PROCESS COMPONENTS AND THEORY
15.2.1 Process Components
Figure 15.1
Figures
15.2 15.3
Table 15.1
Exhibit E-1
RFB 25-26-16
957
Visalia WRF O&M Manual
Figure 15.1: Detailed Process Flow Diagram of Odor Control System. 958
Visalia WRF O&M Manual
Figure 15.2: Foul Air Supply Fans.
Figure 15.3: Biological Filter.
959
Visalia WRF O&M Manual
Table 15.1: Design Specifications for Components of Odor Control System.
Item Units Value Remarks
960
Visalia WRF O&M Manual
15.2.2 Process Theory
15.2.3 Biofilter Operation and Maintenance
15.2.3.1 Operation
Biofilter Irrigation.
Irrigation Frequency.
961
Visalia WRF O&M Manual
Foul Air Temperature.
Visual Inspection of Biofilter.
Odor from the Biofilter.
15.2.3.2 Maintenance
Foul Air Ventilation System.
Drainage Systems.
Changing Biofilter Media.
Table 15.1
962
Visalia WRF O&M Manual
15.3 EQUIPMENT CONTROLS
15.3.1 Automatic/Manual Operation
15.3.1.1 Biofilter Fans (1BFF01 and 1BFF02)
Figure 15.4: Biofilter Fan HOA Selector Switch.
15.3.1.2 Irrigation System
963
Visalia WRF O&M Manual
Figure 15.5: Irrigation System Selector Switch.
15.3.2 Normal Operation
15.4 POWER DISTRIBUTION
964
Visalia WRF O&M Manual
Figure 15.6: Partial Single Line Diagram for Biofilter Fans
15.5 TROUBLESHOOTING GUIDE
15.5.1 Biofilters
Table 15.2: Biofilter Troubleshooting
Problem and Observation(s) Possible Cause(s) Solution(s) 965
Visalia WRF O&M Manual
15.5.2 Make Up Air Unit and Biofilter Fans
15.6 SUPPORTING DOCUMENTS
o
o
o
o
o
o
o
o
966
Exhibit E-2
RFB 25-26-16
967
968
969
970
971
972
973
974
975
976
Wednesday, June 24, 2026
Attention: Bidding Contractors
Reference: RFB 25-26-16 Biofilter Media Replacement and Inspection, Testing at Visalia Water Reclamation Plant
RFB No. 25-26-16
Specification Section 10001 – Odor Control Biofilter Number 1 (BF01) Subject: GES Fiber-Max™ Media Proposal #4544
GES Biotek is pleased to present the following proposal for the supply of Fiber-Max™ biofilter wood chip media for the Odor Control Biofilter Media Replacement project at the Visalia Water Reclamation Plant.
The proposed scope includes approximately 24,750 ft³ (916 yd³) of Fiber-Max™ media for installation in Biofilter Cells A and B. Delivery is anticipated to require approximately ten (10) roll-off double trailer loads, with final load count subject to field loading conditions and material compaction.
Specification Exception and Media Basis - GES Biotek takes exception to the specified media described in Section 2.04 Biofilter Media, which appears to consist of larger components typical of yard-waste composting materials. This type of media has largely fallen out of favor in modern biofiltration applications due to variability in composition, potential contamination, and inconsistent long-term performance.
In contrast, GES Fiber-Max™ is a controlled, engineered organic media manufactured exclusively from trees and large tree branches. The GES Fiber-Max™ material:
• Contains no yard waste, construction debris, demolition materials, commercial wood byproducts • Excludes eucalyptus, cedar, redwood, or any species known to inhibit microbial activity • Provides consistent structure, porosity, and long-term biological stability • Nutrient Conditioning and Biological Support
Prior to shipment, the media is pre-wetted with GES 1578 Super Nutrients and blended with approximately 1–2% GES Gro-Max™ supplemental biological enhancement additives as required to promote rapid establishment of a healthy microbial population.
This conditioning supports the growth of key sulfur-oxidizing microorganisms, including Acidithiobacillus thiooxidans and Acidithiobacillus ferroxidans, enabling efficient biological oxidation of hydrogen sulfide (H₂S) within the media bed.
Proper system startup will require:
• Adequate moisture control (target ~40–60% media moisture) • Humidified inlet air conditions
• Sufficient H₂S loading to sustain microbial activity
977
Scope of Supply - The following items shall be supplied in accordance with RFB No. 25-26-16:
A. Fiber-Max™ biofilter media – 24,750 ft³ (916 yd³) for Cells A and B
1. Base 3’-0” media depth
2. Additional 9” of media for settling of media bed
3. Total bed depth is 3’-9”
B. Freight – approximately ten (10) roll-off double trailer loads to project site C. Biofilter smoke testing (final distribution verification) with report D. Media irrigation coverage inspection
E. Required submittals and media sample
Proposed Fiber-Max™ Media:
The above quoted price includes no sales tax.
The above prices are firm for a period of 30 days from the date of this proposal.
EXCLUSION: Items not specifically quoted above are EXCLUDED.
FREIGHT: Delivered to project site, freight included
DELIVERY: Delivered to project site; shipments scheduled to align with plant operations Payment Terms:
All orders are submitted and subject to our Credit Services Department review and approval. NO RETAINER ALLOWANCE unless otherwise negotiated. Payment terms shall be:
• 25% deposit with purchase order
• NET 30 days each invoice
Delivery Schedule:
The media delivery will be scheduled for 5-6 weeks after the notice to proceed is received.
Truckload deliveries shall be scheduled to assist with the plant unloading schedule.
Items to be provided “By Others”:
The following shall be by others for the above:
• Unloading, and installation of the supplied media
• BacTee Floor replacements
• Liner replacement or modifications\
• TenDrain screen
• Demolition requirements
• Temporary odor control system and controls
• Spray nozzles, Interconnecting PVC piping and valves
• Adjusting and Air Balancing of the Equipment with Report Description Total
24,750ft³ of Fiber-Max™ Media and Smoke Test $
Freight to Visalia, CA 93277 – Ten (10) Roll Off Doubles $ Total $
978
GES Biotek is confident that the proposed Fiber-Max™ media provides a reliable, engineered approach to biofiltration with improved consistency, biological performance, and reduced operational risk compared to conventional compost-based media. We appreciate your consideration and look forward to supporting this project.
Regards,
Steve McCance Steve McCance
Vice President of Operations
GES Biotek, LLC
Office Phone: (630) 473-3874
Cell Phone: (909) 677-1019 (Preferred)
E-Mail: [email protected]
Website: www.gesbiotek.com
Visalia Water Reclamation Plant Project 6.24.2026 Proposal #4544 Encl: GES Terms and Conditions of Sale
Fiber-Max™ Sales Sheet
979
Biofilter Media Replacement & Associated Equipment Inspection
OWNERSHIP DISCLOSURE AND CALIFORNIA LEVINE ACT STATEMENT The following disclosure and statement apply to the Bidder/Proposer/Contractor/Consultant/ Vendor/Supplier or Company:
1. submitting a bid or proposal in response to a solicitation by City of Visalia; or
2. as Awardee of a contract/purchase order which is subject to approval by the Visalia City Council.
OWNERSHIP DISCLOSURE _________________________________________________________________________________________________________ Name of Bidder/Proposer/Contractor/Consultant/Vendor/Supplier or Company _________________________________________________________________________________________________________ Address List the names of all principals, partners, and/or trustees. For corporations, provide names of officers, directors and all stockholders owning more than 10% equity interest in corporation: ___________________________________________________________________________________________________________ ___________________________________________________________________________________________________________ ___________________________________________________________________________________________________________ CALIFORNIA LEVINE ACT STATEMENT California Government Code Section 84308, also know as the “Levine Act,” can prohibit members of the Visalia City Council from participating in any action related to a contract if he or she receives any political contributions totaling more than $500 within the previous twelve (12) months, and for twelve (12) months following the date a final decision concerning the contract has been made, from the person or company awarded the contract. The Levine Act also requires disclosure of such contribution(s) by a party to be awarded a specific contract.
The following website contains a list of current Visalia City Council Members, https://www.visalia.city/government/city_council/default.asp. You are responsible for reviewing the names of Visalia City Council Members prior to making the following disclosure:
1. Have you or your company, or any agent on behalf of you or your company, made any political contributions of more than $500 to a Visalia City Council Member in the twelve (12) months preceding the date of the submission of your proposals or the anticipated date of any City Council action related to this contract?
YES:_____ NO:_____. If yes, please identify the City Council Member(s) and date(s) of contribution in the space below:
Council Member(s) Name Date of Contribution(s) _____________________________ ___________________________ Answering YES, does not preclude the City of Visalia from awarding a contract to your firm or from taking any subsequent action related to the contract. It does, however, preclude the identified Visalia City Council Member(s) from participating in any actions related to this contract.
NOTICE: The disclosure duty under state law continues for twelve (12) months after the award. If the above information regarding contributions changes during this time after the award, then the awardee is required to update this disclosure form. _____________________________________________________________________________________________ Print or Type Name of Bidder/Proposer/Contractor/Consultant/Supplier/Vendor/Company
Signature of Company Authorized Individual Print or Type Name of Authorized Individual Date W. M. Lyles Co.
525 W. Alluvial Ave., Fresno, CA 93711
Lyles Construction Group - holds stock ownership of W. M. Lyles Co., New England Sheet Metal and Mechanical Co., Advanced Integration & Controls, and American Paving Co., affiliated construction companies.
Each of the aforementioned companies are wholly owned, qualified Subchapter S Subsidiaries of Lyles Construction Group.
X
W. M. Lyles Co.
Ruben Moreno, Jr., Secretary
07/31/2026
980
Visalia City Council
Staff Report
Visalia City Council
707 W. Acequia
Visalia, CA 93291
File #: 26-0091 Agenda Date: 8/17/2026 Agenda #: 9.
Agenda Item Wording:
Visalia Health and Wellness Clinic administration and operation - Authorize the City Manager to execute an amendment to extend the agreement for clinic administration and operation with Elite Corporate Medical Services not to exceed $330,000, for one year ending June 30, 2027.
Agenda Date: 08/17/2026
Prepared by: Andrew Guzman, Risk Manager, [email protected], (559) 713-4335; Shonna Oneal, Administrative Services Director, [email protected], (559) 713-4053 Department Recommendation: Staff recommends that the Visalia City Council authorize the City Manager to execute an amendment extending the agreement with Elite Corporate Medical Services, Inc. for one year, ending June 30, 2027, in an amount not to exceed $330,000.
Summary:
The City of Visalia has operated a Health & Wellness Clinic for employees, retirees, and eligible dependents since October 2012. The clinic provides primary and preventive medical care to participants enrolled in a City health plan and also serves as the City’s occupational health provider by performing pre-employment physicals, DOT physicals, and medical services required for regulatory safety compliance. Elite Corporate Medical Services, Inc. administers and operates the clinic.
Between May 1, 2025, and April 30, 2026, the clinic recorded 1,824 patient visits, including 1,539 standard medical visits and 285 occupational health visits. Voluntary patient surveys administered by Elite indicate that patients would have otherwise sought care through an emergency room, urgent care facility, or another primary care provider if the clinic was not available to them. Because Clinic services are provided through the City's fixed-fee agreement rather than through the City's selffunded medical plan, these services help reduce claims activity that would otherwise be submitted to the medical plan.
Elite has proposed a 3% increase to the monthly administration fee, increasing the City’s annual cost from approximately $319,246.36 to $328,468.80. This increase is included within the adopted budget, and no additional appropriation is required.
Staff recommends a one-year extension of the agreement to maintain uninterrupted clinic operations while the City completes the competitive bidding process for future clinic administration services.
Background Discussion:
The City of Visalia Health and Wellness Clinic (“Clinic”) opened in October 2012 to address rising healthcare costs and promote health and wellness with the employee population. Elite Corporate Medical Services, Inc. (“Elite”) was selected as the administrator and has operated the Clinic Visalia City Council Page 1 of 3 Printed on 8/12/2026
powered by Legistar™981
File #: 26-0091 Agenda Date: 8/17/2026 Agenda #: 9.
continuously since its inception.
The Clinic operates Monday through Friday from 8:00 am to 6:00 pm and Saturday from 8:00 am to 3:00 pm. Clinic visits are available at no cost to benefit-eligible employees and retirees enrolled in the City’s EPO and PPO medical plans. Participants enrolled in the High Deductible PPO plan are responsible for the cost of the visit at the time of service to maintain Health Savings Account eligibility.
Clinic services can be broken into three categories:
· Medical services for health plan participants, including acute and episodic care, chronic condition diagnosis and treatment, lab work, and an in-house pharmacy for common nonnarcotic medication. Care also includes wellness and prevention services such as annual health screenings and sport physicals.
· Occupational health services, including pre-employment physicals, DMV/DOT physicals, and HazMat physicals.
· Safety compliance for the City’s Bloodborne Pathogen Exposure Control Plan by providing vaccinations, tuberculosis screening, Hepatitis A and B, and measles, mumps, and rubella (MMR) immunizations for employees whose job duties require them.
During the period of May 1, 2025 through April 30, 2026, the clinic recorded the following visit information:
Standard medical visits: 1,539
Occupational medical services: 285
DOT physicals: 60
Total encounters: 1,824
The City's annual cost for Clinic administration comes to an all-inclusive cost of approximately $175 per patient encounter. This fixed-cost model also includes occupational health services, regulatory safety compliance activities, and other operational services that would otherwise require coordination with external providers.
Patients are offered a voluntary survey after their appointment asking where they would have sought care had the Clinic not been an available option. Of those responding, 56% indicated that they would have gone to the emergency room or urgent care, 29% would have seen another primary care physician, and 15% would not have sought care at all.
Because Clinic services are provided through a fixed-fee agreement rather than through the City's self-funded medical plan, they help reduce claims activity that would otherwise be submitted to the medical plan. The clinic also provides many employees with convenient access to care, allowing them to receive treatment in a timely manner at a low, or no cost.
Beyond cost considerations, the Clinic offers employees a practical alternative to the emergency room and urgent care, both of which typically involve long wait times and carry the risk of a secondary exposure to illness in the waiting room.
The Clinic has operated with the same administrator since October 2012. Staff intends to issue a Visalia City Council Page 2 of 3 Printed on 8/12/2026
powered by Legistar™982
File #: 26-0091 Agenda Date: 8/17/2026 Agenda #: 9.
request for proposal to evaluate available service providers and current market pricing. Staff recommends a one-year extension with Elite to maintain the continuity of operations and continued occupational health services while completing the competitive bid process.
Fiscal Impact including annual maintenance and operating costs: The total cost for this one-year agreement is an annual amount not to exceed $330,000. Clinic administration: $316,636.80; On-site medications: $9,000.00; Janitorial Service: $2,832.00. This amount is already included in the adopted budget, and no additional appropriation is required.
Prior Council Action: Council approved the establishment of a Health & Wellness Clinic in 2012 and authorized a contract with Elite Corporate Medical Services to provide administration. In 2015, Council approved an amendment to the contract to allow for expanded hours. In 2021, Council approved a sole-source 3-year contract with Elite for continued operation of the Clinic.
Alternatives: Do not approve the agreement and discontinue the Clinic. This alternative is not recommended. Discontinuing the Clinic will remove a lower-cost option for care for employees and create disruption for human resources testing and safety compliance services, and require the City to transition these services to external providers, which may result in increased administrative coordination and less convenient access to care for employees.
Recommended Motion (and Alternative Motions if expected):
I move to authorize the City Manager to execute an agreement to extend the agreement with Elite Corporate Medical Services, Inc. for the administration and operation of the City of Visalia Health & Wellness Clinic through June 30, 2027, in an amount not to exceed $330,000.
Environmental Assessment Status: N/A
CEQA Review: N/A
Deadline for Action: 08/17/2026
Attachments: Amendment to Agreement to Provide On-Site Medical Services Between City of Visalia and Elite Corporate Wellness
Strategic Goal: Indicates which City Strategic Goal(s) this item supports. Check all that apply. ☐
Economic
Vitality
☒
Organizational
Excellence
☐
Fiscal
Strength
☐
Infrastructure &
Growth
☐
Quality of
Life
Visalia City Council Page 3 of 3 Printed on 8/12/2026
powered by Legistar™983
Amendment to Agreement to Provide On-Site Medical Services Between City of Visalia and Elite Corporate Wellness
This amendment entered into this __________________ day of __________, 2026 by and between the City of Visalia, a Municipal Corporation and charter law city of the State of California (hereinafter “CITY”), and Elite Corporate Wellness (hereinafter “ECW”).
R E C I T A L S
WHEREAS, the CITY and ECW entered into an “Agreement To Provide On-Site Medical Services” dated June 13, 2012, for the administration and operation of the City of Visalia Health & Wellness Clinic (the “Agreement”); and
WHEREAS, the Agreement has been amended from time to time by mutual agreement of the parties; and
WHEREAS, the parties desire to extend the term of the Agreement through June 30, 2027, and to adjust the compensation payable under the Agreement; and WHEREAS, the purpose of this Amendment is to document the amended terms and conditions of the Agreement.
NOW, THEREFORE, based upon mutual covenants contained herein, the parties agree as follows:
1. The term of the Agreement is hereby extended through June 30, 2027.
2. The compensation payable under the Agreement shall be increased to $27,372.40 per month. Total compensation payable during the term of this Amendment shall not exceed Three Hundred Thirty Thousand Dollars ($330,000.00).
Except as expressly amended herein, all other provisions of the Agreement shall remain unchanged and in full force and effect.
IN WITNESS WHEREOF, the parties hereto have entered into this Agreement on the date first written above.
CITY OF VISALIA
By:____________________________
Leslie Caviglia, City Manager
By:____________________________
Andrew Guzman, Risk Manager
ELITE CORPORATE WELLNESS
By:____________________________
984
Visalia City Council
Staff Report
Visalia City Council
707 W. Acequia
Visalia, CA 93291
File #: 26-0098 Agenda Date: 8/17/2026 Agenda #: 10.
Agenda Item Wording:
Partial notice of completion - Request authorization to file a partial notice of completion for the Riggin Avenue widening project from Kelsey Street to Shirk Street.
Agenda Date: 08/17/2026
Prepared by:
Bryce Nagel, Assistant Engineer, (559) 713-4197, [email protected] Christopher Crawford, City Engineer, (559) 713-4331, [email protected] Jason Huckleberry, Engineering & Building Director, (559) 713-4495, [email protected] Department Recommendation: Staff recommends that the City Council authorize city staff to file a partial notice of completion for the Riggin Avenue widening project from Kelsey Street to Shirk Street.
Summary:
The Riggin Avenue widening project spanned from Kelsey St to Shirk St and consisted of widening the existing 2-lane street to a divided 4-lane street. Agee Construction Inc. was awarded the construction contract for the project with an initial amount of $8,098,281.00. The final construction cost was $9,082,769.10, an increase of $984,488.10. This project is complete except for the final installation of streetlights. During construction, it was found that the standard street light poles would conflict with several of the large Southern California Edison power poles and needed to be reordered.
The street light poles have been ordered but are a long lead time. Once delivered, the contractor will complete the installation and City staff will be coming back to Council for the final NOC of the project and release the remaining retention.
This partial NOC will be releasing the majority of the project’s 5% retention that is held, at the amount of $397,437.48. The remaining retention to be released will be a combination of the cost of procuring the poles at $45,300.98, which was done through a change order, and another $11,400 which is the 5% retention held from the streetlight single mast arm bid item, which covers the cost of installation. A total of $56,700.98 will be held from this retention release.
Background Discussion:
The Riggin Avenue widening project spanned from Kelsey Street to Shirk Street and consisted of widening the existing two-lane roadway into a divided four-lane roadway. Improvements included construction of center medians, landscaping, street lighting, interconnect conduit, storm drainage, turn pockets, Class IV bike lanes, Cal Water main installation, and signalization of the Riggin Avenue and Shirk Street intersection.
Industrial and residential development in the surrounding areas has increased significantly over the past ten years, resulting in greater traffic congestion in this area of the city. The widening of this segment of Riggin Avenue between Kelsey Street and Shirk Street has helped alleviate this congestion. Additionally, the traffic signal at the intersection of Riggin Ave and Shirk Street has Visalia City Council Page 1 of 5 Printed on 8/12/2026
powered by Legistar™985
File #: 26-0098 Agenda Date: 8/17/2026 Agenda #: 10.
congestion. Additionally, the traffic signal at the intersection of Riggin Ave and Shirk Street has helped with access to SR 198 and SR 99 interchanges along those respective roadways.
The project required the contractor to maintain a single lane of travel in both the east and westbound direction along Riggin Avenue throughout construction. A construction management firm was hired by the City to manage public outreach and to work with the contractor to minimize traffic impacts during construction and ensure the safety of the motoring public.
The construction contract was awarded in April 2025, and construction started in September 2025.
The project experienced several delays due to seasonal rain events, Southern California Edison relocations, and the arrival of long lead time items. The original completion date was estimated for mid-March 2026. However, due to these impacts, the roadway itself opened in May 2026, with light poles for the north side of Riggin expecting to arrive and be installed in October of 2026. This partial notice of completion is being recorded to allow for partial release of retention and the start of the warranty period of the areas that are finished.
Fiscal Impact: The Riggin Avenue widening project is a multi-funded project with funds budgeted from Transportation Impact Fee (241), Measure R Regional Fund (133), and an Economic Development Administration Grant.
See the project funding breakdown below:
Riggin Widening Project Kelsey to Shirk Budget
Riggin Avenue Project Final Budget (CP0398)
Measure R Regional Funds (Fund 133) $4,265,000
Traffic Impact Fee (Fund 241) $4,775,000
Economic Development Administration Grant $4,000,000
Total Project Funding $13,040,000
Estimated Final Project Costs:
Project Management & Misc. $211,050
Design Services $325,383
Land Acquisition & Acquisition Services (Right-of-way)$1,169,620 Utility Relocation (SCE relocation Agreement) $1,112,520 Construction (Agee Construction Corp) $8,098,281
Construction Change Orders $984,488.10
Cal Water Main Reimbursement ($676,173)
Traffic Signal Pole $105,462
Equipment Purchase $18,310
Construction Management (Estimated Final) $335,000
Construction Services (Material Testing, Inspection, Survey) ~ (8.5%) $300,000 Total Estimated Project Costs: $11,983,941.10
Estimated amount to be returned to funding sources: $1,056,058.90 Construction Retention Release:
Total Construction Retention - 5% of Construction & CO’s $454,138.46 ibhld il lihlilld ( CO 10 & % f id 1) ($60098)
Visalia City Council Page 2 of 5 Printed on 8/12/2026
powered by Legistar™986
File #: 26-0098 Agenda Date: 8/17/2026 Agenda #: 10.
g
Equipment Purchase $18,310
Construction Management (Estimated Final) $335,000
Construction Services (Material Testing, Inspection, Survey) ~ (8.5%) $300,000 Total Estimated Project Costs: $11,983,941.10
Estimated amount to be returned to funding sources: $1,056,058.90 Construction Retention Release:
Total Construction Retention - 5% of Construction & CO’s $454,138.46 Retention to be held until light poles are installed ( CO #10 & 5% of Bid Item 71) ($56,700.98) Retention to be released from this Partial NOC: $397,437.48 The estimated amount of funds to be returned will be sent back to the original funding sources with amounts going back to the Transportation Impact Fee (241) and Measure R Regional Fund (133).
The Economic Development Administration Grant is fully expended from this project.
Prior Council Action:
June 1, 2026
Council approved construction change order #7 in the amount of $189,175.75 to Agee Construction Corp for the Riggin Avenue Widening Project Kelsey St to Shirk St.
December 15, 2025
Council approved construction change order #1 in the amount of $346,736 to Agee Construction Corp for the Riggin Avenue Widening Project Kelsey St to Shirk St.
May 19, 2025
Council received staff presentation outlining the construction phases of work, traffic detours, and resident impacts for the Riggin Avenue Widening Project Kelsey St to Shirk St.
April 21, 2025
Council authorized the purchase of traffic signal poles from Jam Services, Inc., for $105,462.00, for the Riggin Ave. and Shirk St intersection associated with the Riggin Widening project from Kelsey St. to Shirk St.
April 21, 2025
Council authorized the City Manager to award the construction contract with Agee Construction Corporation for the Riggin Widening project from Kelsey St. to Shirk St. in the amount of $8,098,281.00; authorized the transfer of Measure R Regional Funds and the amendment to Measure R Supplemental Agreements.
October 21, 2024
Council Authorized the City Manager to execute an agreement with NV5, Inc. to provide construction management services for two City projects 1) Shirk Street Capacity Enhancement Project from School Ave to Riggin Ave and 2) Riggin Avenue Widening Project from Kelsey St to Shirk St in the amount of $545,707.60 & $259,369.23 respectively, combined total of $805,076.83 August 5, 2024
Council authorized the execution of Southern California Edison (SCE) Facilities Relocation Agreement for $1,081,000.00 and adopt resolution 2024-46 for the Riggin Avenue Widening Project Kelsey St to Shirk St. Project.
Visalia City Council Page 3 of 5 Printed on 8/12/2026
powered by Legistar™987
File #: 26-0098 Agenda Date: 8/17/2026 Agenda #: 10.
October 17, 2022
Council accepted grant award from the U.S. Economic Administration (EDA) for $4,000,000 and executed the EDA grant agreement for the construction of Riggin Avenue Widening project from Kelsey St to Shirk St.
March 21, 2022
Adopted resolution No. 2022-09 certifying Mitigated Negative Declaration No. 2021-62 prepared for CEQA compliance as part of the Economic Development Administration (EDA) ARPA Grant for construction of the Riggin Widening Project from Kelsey Street to Shirk Street (State clearing house No. 2022010046) (Resolution No. 2022-09 required).
March 15, 2021
Conference with Real Property Negotiators (Pursuant to G.C. Section 54956.8 Property: Portion of APN 077-200-006 generally located at the northwest corner of the intersection of Riggin Avenue and Shirk Street.
Conference with Real Property Negotiators (Pursuant to G.C. Section 54956.8 Property: Portion of APN 077-100-088 generally located at the northeast corner of the intersection of Riggin Avenue and Shirk Street.
Conference with Real Property Negotiators (Pursuant to G.C. Section 54956.8 Property: Portion of APN 077-480-001 generally located at the northwest corner of the intersection of Riggin Avenue and Kelsey Street.
September 8, 2020
Conference with Real Property Negotiators (Pursuant to G.C. Section 54956.8 Property: Portion of APN 077-480-001 generally located at the northwest corner of the intersection of Riggin Avenue and Kelsey Street.
August 17, 2020
Council authorized the City Manager to enter into a contract with 4Creeks Inc., for RFP 19-20-60 to prepare Plans, Specifications, Estimates, and Environmental Services for the Riggin Avenue Widening Project from Kelsey Street to Shirk Street, in the amount not to exceed $200,000.00.
April 6, 2020
Council authorized the execution of a measure R Supplement Agreement with the Tulare County Association of Governments (TCAG) to secure $3.5 million of Measure R Regional Funds for the Riggin Ave. Widening from Kelsey St to Shirk
Alternatives: None recommended.
Recommended Motion (and Alternative Motions if expected):
I move for the City Council to authorize city staff to file a partial notice of completion for the Riggin Avenue widening project (Kelsey Street to Shirk Street).
Visalia City Council Page 4 of 5 Printed on 8/12/2026
powered by Legistar™988
File #: 26-0098 Agenda Date: 8/17/2026 Agenda #: 10.
Environmental Assessment Status: None required.
CEQA Review: CEQA Exemption - 2024-48
Deadline for Action: 08/17/2026
Attachments: 1. Project Location Map 2. Draft Retention Release Memo Strategic Goal: Indicates which City Strategic Goal(s) this item supports. Check all that apply. ☒
Economic
Vitality
☐
Organizational
Excellence
☐
Fiscal
Strength
☒
Infrastructure &
Growth
☒
Quality of
Life
Visalia City Council Page 5 of 5 Printed on 8/12/2026
powered by Legistar™989
Rd 92
Ave 320
W Doe Ave
N Shirk St
W Goshen Ave
N Plaza Dr
N Kelsey St
W Riggin Ave Ave 312
W Kibler Ave
W Sunnyview Ave
W Ferguson Ave N Plaza Dr
² Location Map
Riggin Ave Widening - Kelsey to Shirk
Riggin Avenue
(Kelsey to Shirk)
990
315 E. Acequia Ave. • Visalia, CA 93291 P 559.713.4444 W visalia.gov Engineering & Building Department
Engineering Division
NOTICE FOR RELEASE OF RETENTION
To: Agee Construction Corporation
PO Box 629
Clovis, CA, CA 93613
Date: 08/17/2026
Project Description: Riggin Widening Project from Kelsey Street to Shirk Street Project No.: 3010-72000/CP0398-999
You are hereby notified for a partial release of retention for the Riggin Widening Project from Kelsey Street to Shirk Street. All remaining WORK shall continue to comply with the terms and conditions set forth in the Construction Contract dated May 30, 2025. This release of retention is being issued while the project is awaiting light poles to be furnished and installed. Agee Construction Corporation shall be responsible for the full completion of all WORK on the Riggin Widening Project from Kelsey Street to Shirk Street. Payment of $56,700.98 will be held from Agee Construction Corporation for the remaining work until the project is deemed complete.
City of Visalia Official
By: Bryce Nagel
Print Name
Title: Assistant Engineer
ACCEPTANCE OF NOTICE FOR RELEASE OF RETENTION
Receipt of the above NOTICE FOR RELEASE OF RETENTION is hereby acknowledged. All attachments are hereby incorporated and made a binding part of this acknowledgment.
By:
Signature
Title:
Print Name & Title
This day of , 2025
991
Visalia City Council
Staff Report
Visalia City Council
707 W. Acequia
Visalia, CA 93291
File #: 26-0099 Agenda Date: 8/17/2026 Agenda #: 11.
Agenda Item Wording:
Award of annual contract for sports park mowing and aeration services - Authorize the City Manager to award the annual contract for sports park mowing and aeration services to Perfect Care Landscape in an annual amount not to exceed $450,000.
Agenda Date: 08/17/2026
Prepared by: Daryl Tillman, Parks Maintenance Supervisor, 559-713-4435; [email protected]; 559-713-4435; Ivan Nicar, Parks and Facilities Manager, 559-713-4564; [email protected]; Jason Glick, Parks and Recreation Director, 559-713-4042; [email protected].
Department Recommendation: Staff recommends that the City Council authorize the City Manager to award RFB No. 25-26-48 for the annual contract for sports park mowing and aeration services to Perfect Care Landscape of Tulare, California, in an annual amount not to exceed $450,000.
Summary:
The proposed contract will provide routine mowing, aeration, and related turf maintenance services for City-owned sports fields to maintain safe, healthy, and playable athletic fields throughout the year.
Services include scheduled mowing of sports turf, seasonal core aeration, trimming and edging as required, debris removal associated with mowing operations, and other related maintenance necessary to preserve high-quality playing surfaces. The contractor will furnish all labor, equipment, materials, and transportation necessary to perform the work in accordance with City specifications.
Maintaining athletic fields throughout the City’s park system with regular mowing and aeration promotes healthy turf growth, improves field drainage, reduces soil compaction, enhances player safety, and extends the useful life of City sports fields. Awarding this annual contract will provide the City with reliable, consistent maintenance services while allowing staff to efficiently address seasonal workload demands and maintain service levels at City sports fields.
Background Discussion:
On May 20 and May 27, 2026, the City advertised Request for Bids (RFB) No. 25-26-48 in the Visalia Times-Delta. The RFB was also posted on BidNet Direct, and bid notifications were distributed to prospective contractors.
The City conducted mandatory pre-bid meetings on June 2, 2026, at 9:00 a.m., and June 4, 2026, at 1:00 p.m., in the City Council Chambers. During these meetings, staff reviewed the scope of work, contract requirements, and responded to questions from prospective bidders.
On June 18, 2026, the City received three responsive bids. Staff evaluated each bid for responsiveness, mathematical accuracy, and compliance with the requirements of the RFB.
Visalia City Council Page 1 of 3 Printed on 8/12/2026
powered by Legistar™992
File #: 26-0099 Agenda Date: 8/17/2026 Agenda #: 11.
BIDDER SUMMARY
Bidders Name Location Total Bid Amount
Visalia Landscape and Tree
Company
Visalia, CA Bid Withdrawn
Perfect Care Landscape Tulare, CA $449,212.92
Pride Industries Roseville, CA $1,079,815.24
Visalia Landscape and Tree Company submitted the apparent low bid. During the bid review process, staff identified what appeared to be an omission of costs associated with furnishing and delivering sand required under the contract. On July 2, 2026, Visalia Landscape and Tree Company, submitted a written request to withdraw their bid.
Staff subsequently evaluated the second-lowest bid submitted by Perfect Care Landscape and determined that it was complete, responsive, and met all requirements of the solicitation.
Perfect Care Landscape has successfully performed landscape maintenance services for the City on previous projects. Staff contacted the contractor’s references and confirmed the firm’s qualifications, quality of work, and satisfactory performance. Staff also verified that the contractor’s Department of Industrial Relations (DIR) registration is current, its California State License Board (CSLB) C-27 Landscaping Contractor license is active and in good standing, and that the contractor is not listed on the Division of Labor Standards Enforcement (DLSE) debarment list.
This agreement is classified as a public works maintenance contract and is subject to all applicable State prevailing wage requirements, including contractor registration with the Department of Industrial Relations, submission of certified payroll records, and compliance with the City’s Labor Compliance Manual, which was included in the contract specifications.
The initial contract term will be twelve (12) months, with the option to renew annually for up to four (4) additional one-year terms, subject to satisfactory contractor performance, the availability of funding, and mutual agreement between the City and the contractor.
Annual price adjustments at each renewal will be based on the Consumer Price Index (CPI), as provided in the contract documents.
If additional City-owned sports parks are added during the contract term, compensation for those services will be calculated using the contractor’s approved unit prices in accordance with the contract provisions.
Fiscal Impact including annual maintenance and operating costs: Funding for the annual contract for sports park mowing and aeration services is included within the Parks Division operating budget in the General Fund. The annual contract amount will not exceed $450,000. No budget amendment is required.
Prior Council Action: None
Alternatives: Reject all bids and direct staff to re-advertise the project through a new Request for Visalia City Council Page 2 of 3 Printed on 8/12/2026
powered by Legistar™993
File #: 26-0099 Agenda Date: 8/17/2026 Agenda #: 11.
Bids.
Recommended Motion (and Alternative Motions if expected):
I move to authorize the City Manager to award the annual contract for sports park mowing and aeration services to Perfect Care Landscape in an annual amount not to exceed $450,000, and authorize the City Manager to execute all related contract documents.
Environmental Assessment Status: N/A
CEQA Review: N/A
Deadline for Action: 08/17/2026
Attachments: Annual Contract for Sports Park Mowing and Aeration Service, RFB No. 25-26-48, Perfect Care Landscape’s signed bid form, Bid Summary, Exhibit B-7 Ownership Disclosure and Levine Act Statement.
Strategic Goal: Indicates which City Strategic Goal(s) this item supports. Check all that apply. ☐
Economic
Vitality
☐
Organizational
Excellence
☐
Fiscal
Strength
☒
Infrastructure &
Growth
☒
Quality of
Life
Visalia City Council Page 3 of 3 Printed on 8/12/2026
powered by Legistar™994
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES Page i
CITY OF VISALIA
REQUEST FOR BID (“RFB”)
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK
MOWING & AERATION SERVICES
BIDS DUE NO LATER THAN 1:00 P.M. ON THURSDAY, JUNE 18, 2026 The City of Visalia expressly reserves the right to modify or withdraw from the process initiated and described herein. No rights shall be vested in any party, individual, or entity by virtue of its preparation to participate in, or its participation in, such process. The City expressly reserves the right to modify, for any reason, the schedule and any provision contained herein. The City reserves to itself the selection of winning respondent(s), if any, in the exercise of its sole discretion. No binding commitment shall arise on the part of the City to any respondent under this Request for Bid until and unless the parties sign documents of agreement that become effective in accordance with their terms. Responses to this RFB, however, shall be held firm by Respondent for at least ninety (90) days.
PUBLIC WORKS CONTRACT: This is a Public Works Maintenance Contract, therefore it is subject to registration with the Department of Industrial Relations, payment of prevailing wages, submission of certified payroll records to the Labor Commissioner, and other requirements listed in the City of Visalia Labor Compliance Manual (attached). All Bidders, Contractors, and Subcontractors must be registered with the Department of Industrial Relations.
Advertisement Dates: May 20, 2026
May 27, 2026
995
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES Page ii
TABLE OF CONTENTS
I. DEFINITIONS.......................................................................................................................... 1 II. INTRODUCTION..................................................................................................................... 1 III. DEPARTMENT OF INDUSTRIAL RELATIONS REQUIREMENTS ...................................... 1 IV. INSTRUCTIONS ..................................................................................................................... 4 V. SCOPE OF SERVICES/PROJECT ........................................................................................ 6 VI. PRE-BID AND PRECONSTRUCTION MEETINGS ............................................................... 8 VII. BID OPENING AND CONFIDENTIALITY .............................................................................. 8 VIII. AWARD................................................................................................................................... 8 IX. PROTESTS/APPEALS........................................................................................................... 9 X. SPECIAL CONDITIONS ......................................................................................................... 9 XI. GENERAL CONDITIONS ...................................................................................................... 12 XII. POST AWARD RESPONSIBILITIES .................................................................................... 14
EXHIBITS
A. BID FORM
B. CERTIFICATIONS, AFFIDAVITS, ASSURANCES, STATEMENTS, WAIVERS, AND
QUESTIONNAIRES WHICH MUST ACCOMPANY BID FORM
B-1. Equal Employment Opportunity Compliance Certificate B-2. Certificate of Non-segregated Facilities
B-3. Non-Collusion Affidavit
B-4. Worker’s Compensation Insurance Certificate
B-5. Anti-Kickback Compliance Certificate
B-6. Americans with Disabilities Act Compliance Certificate B-7. Disclosure Form and California Levine Act
B-8. Drug-Free Workplace
B-9. Iran Contracting Act Certification
C. SAMPLE PROJECT AGREEMENT WITH ATTACHMENTS
ATTACHMENT 1 - GENERAL CONTRACT PROVISIONS
ATTACHMENT 2 - INSURANCE REQUIREMENTS
D-1. SPORTS PARK SERVICE AREA &MOWING FREQUENCY SCHEDULE D-2. SPORTS FIELD AERATION, SCALPING, & SERVICE FREQUENCIES D-3. SPORTS PARK WEEKLY MOWING ROUTES
D-4. MAP OF ATHLETIC TURF AREAS AND COMMON AREA
D-5. MAP OF CITY SPORTS PARKS
D-6. STATE OF CALIFORNIA PREVAILING WAGE RATES
D-7. LABOR COMPLIANCE MANUAL
996
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
I. DEFINITIONS
For the purposes of RFB NO. 25-26-48, the following terms shall have the meanings indicated:
1. “City” means the City of Visalia
2. “City Council” means the Council of the City of Visalia
3. "Bidder", "Vendor", "Supplier", “Consultant”, “Contractor”, and “Subrecipient” are used interchangeably throughout this invitation to mean the person, firm, or corporation or other entity submitting a Bid in response to the Request for Bid.
4. “Bid” and “Proposal” are used interchangeably to mean an individual’s or entity’s offer in response to this Request for Bid.
5. “RFB” means Request for Bid No. 25-26-48.
II. INTRODUCTION
The City of Visalia Purchasing Division is soliciting Bids for an annual contract for mowing and aeration services on a regularly scheduled basis throughout the City of Visalia. The successful bidder shall be responsible for providing all services necessary to fulfill the requirements of this Invitation to Bid upon receipt of the City’s Notice to Proceed.
The initial contract term shall be for a twelve (12) month period and shall, at the City’s option and with the consent of the CONTRACTOR, be extended annually thereafter for four (4) consecutive one-year periods." Bids are being sought from contractors who have a proven record of experience in providing the services required by this Invitation to Bid.
In an effort to encourage local businesses to provide goods and services to the City, the Council has enacted a local preference. The local preference will apply to any business that has a business address within Tulare County for a minimum of six months. A Post Office Box will not be accepted as a business address. The City reserves the right to request proof of Tulare County address.
The local preference for bids consists of a match preference in which a local vendor whose bid is within 5% of the apparent low bidder will be given three (3) business days, from the date notified, to match or beat the low bid. If there is more than one local vendor that is within the 5% range, the offer goes to the local vendor that is closest to the low bid.
Under the requirements of Labor Code section 1782, passed by SB7 and in compliance with City of Visalia Ordinance 2014-13, this public works project is subject to State prevailing wages as specified in the specifications. See Section III for additional Department of Industrial Relations requirements that apply to this project.
The City hereby affirmatively ensures that Minority Business Enterprises and Disadvantaged Business Enterprises (DBE) will be afforded full opportunity to submit proposals in response to this notice. Individuals and/or entities submitting bids/proposals to the City of Visalia will not be discriminated against on the basis of race, religion, color, national origin, ancestry, physical or mental disability, medical condition, genetic information, marital status, gender, gender identity or expression, sexual orientation, or military and veteran status in any consideration leading to the award of contract.
No qualified disabled person shall, on the basis of disability, be excluded from participating in, be denied the benefits of, or otherwise be subjected to discrimination under any program or activity leading to the award of a contract.
Executive Order N-6-22 – Russia Sanctions On March 4, 2022, Governor Gavin Newsom issued Executive Order N-6-22 (the EO) regarding Economic Sanctions against Russia and Russian entities and individuals. “Economic Sanctions” refers to sanctions imposed by the U.S. government in response to Russia’s actions in Ukraine, as well as any sanctions imposed under state law. By submitting a bid or proposal, Contractor represents that it is not a target of Economic Sanctions. Should the State determine Contractor is a target of Economic Sanctions or is conducting prohibited transactions with sanctioned individuals or entities, that shall be 997
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
grounds for rejection of the Contractor’s bid/proposal any time prior to contract execution, or, if determined after contract execution, shall be grounds for termination by the State.
III. DEPARTMENT OF INDUSTRIAL RELATIONS REQUIREMENTS, Public Works Contractor Registration Program and Project Labor Agreements
Notice is hereby given that this contract is considered a public works contract and, therefore, subject to DIR monitoring. All contractors and subcontractors bidding and performing work on Public Works Projects must be currently registered with the California Department of Industrial Relations (DIR). Awarded Contractor is required to furnish electronic payroll records for new projects to the Labor Commissioner.
No contract will be awarded unless that contractor and/or subcontractors are registered with the California Department of Industrial Relations (DIR). Bids by unregistered contractors submitted after March 1, 2026, may be rejected as non-responsive.
A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined in this chapter, unless currently registered and qualified to perform public work pursuant to Section 1725.5. It is not a violation of this section for an unregistered contractor to submit a bid that is authorized by Section 7029.1 of the Business and Professions Code or by Section 10164 or 20103.5 of the Public Contract Code, provided the contractor is registered to perform public work pursuant to Section 1725.5 at the time the contract is awarded.
If a project labor agreement (the term “project labor agreement” is defined in Public Contract Code 2500(b)(1) as a prehire collective bargaining agreement that establishes terms and conditions of employment for a specific construction project or projects and is an agreement described in Section 158(f) of Title 29 of the United States Code) is used, then it must comply with the taxpayer protection provisions set forth in Public Contract Code section 2500(a). City of Visalia has no ordinances requiring or prohibiting such agreements.
The following statements and requirements are to be included in all City of Visalia public work contracts that require the payment of prevailing wages in accordance with the California Labor Code (CLC). This RFB document becomes a part of the public works contract for this project, and therefore, the CLC contract language requirements are incorporated into the contract.
As set forth in CLC section 1771.1(a), all contractors and subcontractors must be currently registered and qualified to perform public work pursuant to CLC section 1725.5 to be qualified to bid, be listed in a bid proposal, or perform any public work for the City of Visalia. Proof of registration for each contractor and subcontractor listed on the bid is required.
As set forth in CLC section 1771.4 (a)(1), notice is given that this project is a public work, subject to compliance monitoring and enforcement by the Department of Industrial Relations. As set forth in CLC section 1771.4(a)(2), the prime contractor is required by the City of Visalia to post job site notices, as prescribed by regulation. Information on required workplace postings may be found on the Department of Labor website at: http://www.dir.ca.gov/wpnodb.html. The contractor and each subcontractor shall maintain all project records required under CLC for public works projects and preserve them for a minimum 3-year period to begin on the date a Notice of Completion is filed for the project. Please refer to the retention period required for any grant or specialized project funding. Some funding sources require an extended time period for records retention.
In accordance with CLC section 1773.2, the contractor is required, by the City of Visalia, to post a copy of the determination of the Director of Labor Standards' prevailing rate of per diem wages for each craft, classification, or type of worker needed to execute the contract at each job site. In accordance with Labor Code section 1776 and its enforcement (1771.4(a)(3)), for initial contracts awarded on or after April 1, 2015, each project contractor and subcontractor shall; 998
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
o Maintain and furnish directly to the Labor Commissioner, bi-weekly, a certified copy of each weekly payroll as specified in section 1776 containing a statement of compliance with labor code sections 1771, 1811, and 1815, signed under penalty of perjury. o Make available or provide a certified copy of these payroll records and their supporting documentation within 10 days to all authorized parties upon written request and be subject to penalties for non-compliance as detailed in Labor Code section 1776. o Inform the City of Visalia of the location of the payroll records kept in compliance with Labor Code section 1776(g) and notify the City of Visalia within 5 working days of any change in their location.
The City of Visalia will comply with any prevailing wage monitoring and enforcement activities required by the labor compliance programs of the Department of Industrial Relations, including the withholding of contract payments in the amount of any underpayment of prevailing wage and applicable penalties as directed by the Department of Labor Standards Enforcement in accordance with CLC section 1727(a).
Any amount withheld will be released as directed by the Labor Commissioner upon receipt of a certified copy of a final order no longer subject to judicial review in accordance with CLC section 1742(f). As set forth in Labor Code section 1775(b), the following subcontractor provisions shall be included in any contract executed between the contractor and a subcontractor for performance of work on this public work project:
o As set forth in CLC section 1775(b)(1), any contract executed between a contractor and a subcontractor for the performance of work on a City of Visalia public works project shall include a copy of the provisions of Labor Code sections 1771, 1776, 1777.5, 1813, and 1815. These labor code sections must be included within or as attachments to the contract. o As set forth in CLC section 1776, the subcontractor shall maintain and furnish directly to the Labor Commissioner, bi-weekly, a certified copy of each weekly payroll as specified in section 1776 containing a statement of compliance with labor code sections 1771, 1776, 1811, and 1815, signed under penalty of perjury.
o As set forth in CLC section 1775(b)(2), the contractor shall monitor the payment of the specified general prevailing rate of per diem wages by the subcontractor to the employees, by periodic review of the certified payroll records of the subcontractor. o As set forth in CLC section 1775(b)(3), upon becoming aware of the failure of the subcontractor to pay his or her workers the specified prevailing rate of wages, the contractor shall diligently take corrective action to halt or rectify the failure, including, but not limited to, retaining sufficient funds due the subcontractor for work performed on the public works project. o As set forth in CLC section 1775(b)(4), prior to making final payment to the subcontractor for work performed on the public works project, the contractor shall obtain an affidavit signed under penalty of perjury from the subcontractor that the subcontractor has paid the specified general prevailing rate of per diem wages to his or her employees on the public works project and any amounts due pursuant to Section 1813. Prior to the release of retention to the contractor, the COV will require a copy of the affidavit(s) completed by each listed subcontractor.
In accordance with CLC section 1777.5(e), prior to commencing work on a contract for public work, every contractor shall submit contract award information to an applicable apprenticeship program that can supply apprentices to the site of the public work.
Only apprentices, as defined in CLC section 3077, in training under apprenticeship standards approved by the Division of Apprenticeship Standards (DAP) and party to written apprentice agreements under CLC section 3070-3098, may be employed at the apprentice wage rate on public works. 999
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
Unless exempted under CLC section 1777.5(j), a contractor working on a public works contract of $30,000 or more shall employ the number of apprentices or the ratio of apprentices to journeymen stipulated in the applicable apprenticeship standards (CLC 1777.5(n)). In no event shall the ratio be less than one hour of apprentice work for every five hours of journeyman work. The prime contractor is responsible for compliance with the requirements of CLC section 1777.5 for all apprenticeable occupations employed on the contract. As stated in 1777.5 (o), the apprenticeship requirement does not apply to contracts of general contractors or to contracts of specialty contractors not bidding for work through a general or prime contractor when the contract is less than thirty thousand dollars ($30,000).
As stated in section 1777.7(e), the prime contractor will not be liable for any penalties assessed for violations of section 1777.5 if they have complied with the following requirements:
o The contract executed between the contractor and the subcontractor for the performance of work on the public works project shall include a copy of the provisions of sections 1771, 1775, 1776, 1777.5, 1813, and 1815. These labor code sections must be included within or as attachments to the contract.
o The contractor shall continually monitor a subcontractor's use of apprentices required to be employed on the public works project pursuant to subdivision (d) of section 1777.5, including, but not limited to, periodic review of the certified payroll of the subcontractor. o Upon becoming aware of a failure of the subcontractor to employ the required number of apprentices, the contractor shall take corrective action, including, but not limited to, retaining funds due to the subcontractor for work performed on the public works project until the failure is corrected. o Prior to making a final payment to the subcontractor for work performed on the public works project, the contractor shall obtain a declaration signed under penalty of perjury from the subcontractor that the subcontractor has employed the required number of apprentices on the public works project. The prime contractor is required to provide a signed affidavit declaring their compliance with California Labor Code sections 1771 (prevailing wage) and 1777.5 (apprenticeship) for all workers employed on the contract before final payment will be made on the contract by the City of Visalia.
Contract inclusion and/or attachments: The following items are required to be included either in the body of, as attachments to, or addenda to all public work contracts:
As set forth in CLC section 1773, the City of Visalia shall obtain the general prevailing rate of per diem wages and the general prevailing rate for holiday and overtime work in the locality in which the public work is to be performed for each craft, classification, or type of worker needed to execute the contract from the Director of Industrial Relations. This will include the apprenticeship prevailing wage for all apprenticeable trades. In accordance with Labor Code section 1773.2, this information is to be included in the contract itself.
10 days before the closing date of the bid, the project manager will review the prevailing wage rates included in any requests for bid proposals for updates and issue an addendum to notify interested bidders of any changes.
General prevailing wage determinations made by the director of industrial relations for journeyman and apprentices may be found at:
http://www.dir.ca.gov/OPRL/PWD/index.htm and
http://www.dir.ca.gov/OPRL/PWAppWage/PWAppWageStart.asp 1000
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
IV. INSTRUCTIONS
1. Fill out attached Bid Form (Exhibit “A”) in ink or typewriting completely.
2. Cross out and initial mistakes in ink and place the correct response next to same.
3. Timely submit Bid in a sealed envelope addressed and marked as follows:
To: City of Visalia Purchasing Division
707 W. Acequia Avenue
Visalia, California 93291
From: Bidders Name & Mailing Address
Marked: Sports Park Mowing & Aeration Services
RFB NO. 25-26-48
Deadline: 1:00 p.m. on Thursday, June 18, 2026
Delivery of Bid: When sending a bid via FedEx, UPS, etc., it is the responsibility of the Bidder to ensure that the bid is received during open office hours. Office Hours are 7:30 am – 5:00 pm Monday through Thursday.
We are closed on Fridays and major holidays. Bids are not delivered or received when the office is closed.
The City utilizes an outside service for delivery and sorting incoming mail, and therefore, mailing a bid via U.S.
Mail is not recommended, as there could be a delay in receiving bids by the deadline. Bids must be received prior to the deadline. The City will not accept a postmark as evidence of delivery.
Night Drop Box: If delivering a bid after hours, a Night Drop Box is located at Visalia City Hall, 707 W.
Acequia Avenue, Visalia, CA 93291. Enter the west parking lot of the building off of Stevenson Street. The Drop Box is labeled “Night Drop” and is located on the building across from the bicycle racks. The Night Drop Box should only be utilized if City Offices are closed. The Night Drop Box is checked prior to the bid deadline.
4. Submit each of the required Certifications, Affidavits, Guarantees, Statements, and Questionnaires, as well as optional waiver(s) to the City with the sealed Bid. City will not consider bids that are not accompanied by the required completed forms.
5. Inquiries: Instructions to Vendor, Specifications, and Bid Forms may be inspected and obtained by visiting our website at Visalia.gov/purchasing or by calling (559) 713-4334. However, to prevent misinterpretations, the Purchasing Division would prefer that all questions be sent by email to [email protected].
All questions regarding this project are due by Tuesday, June 9, 2026 1001
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
V. SCOPE OF SERVICES/PROJECT
ITEM 1: MOWING OF CITY SPORTS PARKS, AERATION, AND SCALPING See Exhibit “D-1” for the list of Parks and square footage. See Exhibit “D-3” for mowing route sheets and addresses. These exhibits identify all turf areas to be maintained under this contract.
Mowing shall be performed Monday through Friday between the hours of 6:00 a.m. and 4:00 p.m. on the designated day per the mowing route schedule. This schedule is designed to ensure mowing is completed prior to scheduled recreational activities. Unless otherwise noted, all locations are on a weekly mowing schedule.
Contractor Responsibilities
Mow all turf areas per the established mowing route. At Riverway Sports Park on Mondays, the turf must be clean and free of debris and trash prior to mowing. Contractor shall allow time for City staff to complete debris removal before mowing begins. Debris removal is typically completed by 8:00 a.m. If there is a debris issue, the contractor is required to contact the city prior to mowing.
Riverway Sports Park: Rotary mowers equipped with mulching blade kits are recommended for use on sports fields and in all common areas. Prior to each mowing, City staff will inspect the underside of mower decks for cleanliness.
Mowing of athletic fields shall be performed using equipment designated exclusively for athletic turf. No other mowers shall be used on these fields to prevent the introduction and spread of weeds from other parks or areas.
Athletic fields include, but are not limited to: Riverway Sports Park (soccer, baseball, softball, and Saputo fields), Plaza Park softball fields, Whitendale softball fields, Jefferson softball field, and Fairview Park.
Edge all turf areas bi-weekly, as designated on scheduled mow days, in all parks per the approved schedule.
Edging shall include sidewalks, curbs, planters, and other areas adjacent to turf. Parks mowed twice per week shall still require edging only bi-weekly.
Trim around trees located within or adjacent to turf areas unless otherwise directed. Trimming shall not occur in areas treated by City crews; however, if weeds appear in these areas, Contractor shall mow them until weed abatement can be applied. Contractor shall be responsible for any damage to trees caused by trimming or mowing equipment.
Blow or sweep all sidewalks, curbs, gutters, and parking lots after each mowing service.
Contractor shall report any unsafe conditions (e.g., broken or vandalized playground equipment, backstops, bleachers, etc.) to the City of Visalia Park Supervisor immediately.
Contractor shall report any broken sprinklers and/or excessively wet or dry areas to the City of Visalia Park Supervisor immediately. If an area is too wet to mow, Contractor shall discontinue mowing in that area and notify the Park Supervisor. Contractor shall coordinate to reschedule mowing within the same week once conditions allow. Contractor shall be responsible for repairing any damage, including ruts, caused by mowing in wet conditions.
Report any large limbs or hanging branches to the City of Visalia Park Supervisor immediately.
Report any unlawful or suspicious activity to the Visalia Police Department immediately.
Report any damaged plants to the City of Visalia Park Supervisor immediately.
Mowers equipped with mulching decks are preferred but not required. If a mower is equipped to bag clippings, Contractor shall be responsible for the collection and proper disposal of clippings at Contractor’s expense, in accordance with applicable green waste recycling requirements. 1002
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
Mowing height shall be maintained as follows:
Warm Season Grass Height: 2 inches
Cool Season Grass Height: 3 inches
All areas shall be mowed on the designated day per the mowing route schedule, as irrigation systems will be turned off on those days to prevent rutting. The Park Supervisor must approve any changes to the mowing schedule. Contractor shall notify the Park Supervisor at least two (2) days in advance of any requested changes to allow for irrigation adjustments.
Bidders shall provide pricing for both the weekly and twice-weekly mowing service options for Riverway Sports Park as outlined in the Bid Form. The City reserves the right to select either service level at the time of award.
ITEM 2: SPORTS FIELD AERATION
Awarded Contractor shall be responsible for aerating designated sports fields three (3) times annually, as specified in this RFB. Please refer to Exhibit “D-2” for locations and detailed specifications.
Awarded Contractor shall provide all equipment, labor, and services necessary to complete the aeration process.
ITEM 3: SPORTS FIELD SCALPING
Awarded Contractor shall be responsible for scalping designated sports fields two (2) times annually, as specified in this RFB. Please refer to Exhibit “D-2” for locations and detailed specifications.
Awarded Contractor shall provide all equipment, labor, and services necessary to complete the scalping process.
SPECIAL NOTES
Contractor shall be responsible for providing all supplies, equipment, and materials necessary to complete the mowing routes.
Safety Data Sheets (SDS) shall be provided to the City of Visalia Park Supervisor upon request. Contractor shall also ensure that all SDS are readily available to their employees when working with any chemicals used during City of Visalia park mowing operations.
Contractor shall maintain the ability to contact the City of Visalia Park Supervisor at all times via cellular phone.
Contractor shall not operate equipment on turf areas other than designated mowing equipment.
Contractor shall meet with the City of Visalia Park Supervisor prior to the start of services to review route locations and become familiar with all parks and mowing locations.
The in-season period shall begin the first week of March and continue through October 31.
During the off-season, parks shall be mowed on a bi-weekly basis following the final full week of in-season mowing. Off-season mowing shall occur from November 1 through February 28.
Contractor shall be responsible for any damage caused to City of Visalia property, including but not limited to trees, structures, sidewalks, turf, and irrigation systems. 1003
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
Miscellaneous Services
On an as-needed basis, the City of Visalia may request the Contractor to perform additional lawn maintenance services, including one-time clean-up and/or irrigation repairs at locations not included in this contract.
For this purpose, the Bidder shall provide an hourly rate as indicated on the bid form. This rate shall apply only when services are pre-approved by the City’s Project Manager.
Any parts required for approved repairs may be reimbursed to the Contractor with prior authorization from the City’s Project Manager. Contractor shall itemize all such work separately on monthly invoices and provide supporting receipts for reimbursement. All additional services shall be authorized in writing prior to commencement.
VI. PRE-BID AND CONTRACT MEETINGS
1. Mandatory Pre-Bid Meetings. Two (2) mandatory pre-Bid meetings have been scheduled. Bidders are required to attend one (1) of the following meetings to be eligible to submit a Bid in response to this RFB:
• Tuesday, June 2, 2026, at 9:00 a.m.
• Thursday, June 4, 2026, at 1:00 p.m.
Both meetings will be held at Riverway Sports Park, located at 3611 N. Dinuba Blvd., Visalia.
Attendance at one (1) of these meetings is required to submit a Bid. Information regarding the project will be provided at that time. It shall be the responsibility of the Contractor to have acquired full knowledge of the job site, scope of work, and any problems or difficulties that may affect the work proposed.
2. Post Award Meeting. Subsequent to the award of the contract, the Contractor shall meet with the Project Manager prior to the start of work to discuss any problems or questions that may arise.
Contractor shall contact the Project Manager within ten (10) days of the date of the Notice to Proceed to arrange this meeting.
City Project Manager: Daryl Tillman
Department: Parks & Urban Forestry
VII. BID OPENING AND CONFIDENTIALITY
1. Bid Opening. Bids shall be opened publicly in the presence of attendees, if any, on Thursday, June 18, 2026, at 1:00 p.m. at City Hall, 707 W Acequia Ave, Visalia, CA. The name of each Bidder and the amount of each Bid shall be open to public inspection at the Bid opening and after an award decision has been made. Other Bid information will not be available for public review during the evaluation phase.
2. Bid Confidentiality. The City favors full and open disclosure of all Bid records. The City will not expend public funds defending claims for access to, inspection of, or to be provided copies of any such records. By submitting a Bid, a Bidder agrees to indemnify and defend the City against all claims or actions brought against it to seek access to, or compel disclosure of, any records or documents in the City’s possession.
After the award, the City intends that its selection process will be open and public.
Respondents are advised that the California Public Records Act (“PRA”) provides that any person may inspect or be provided a copy of any identifiable public record or document that is not exempted from disclosure by the express provisions of the Act. The Federal Freedom of Information Act (“FOIA”) contains a similar provision. Each Bidder shall clearly identify any information within its Bid that it intends to ask the City to withhold as exempt under either the PRA or FOIA. Any information contained in a Bidder’s submission which the Bidder believe qualifies for exemption from public disclosure as “Proprietary” or “Confidential” must be identified as such at the time of first submission of Bidder’s Bid to this RFB. Any failure to 1004
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
identify information contained in a Bidder’s Bid to this RFB as “Proprietary” or “Confidential” shall constitute a waiver of Bidder’s right to object to the release of such information upon request under either Act.
VIII. AWARD
1. Most Responsive, Responsible Bidder. A Contract (substantially similar to that attached hereto as Exhibit “C” with Attachments 1-2) shall be awarded with reasonable promptness by appropriate written notice. Award shall be made to the most responsive, responsible Bidder whose Proposal meets the requirements and criteria set forth in this RFB, price and other factors considered, and whose Bid is determined to result in the optimum economic advantage to the City. A responsible Bidder is one who has the capability, financial capacity, and integrity to perform the contract. A responsive Bidder is one who commits to all of the material terms, for example, price, quantity, quality, and delivery, of this RFB. Contractor must return a signed copy of the contract provided by the City with its Award Notice to City within ten (10) working days of receipt thereof.
2. Reservation of Rights. The City reserves the right to reject any item or items in the Bid; to waive informalities, technical defects, and minor irregularities in Bids received; and to select the Bid(s) deemed most advantageous to the City.
IX. PROTESTS/APPEALS
Because it is essential that Bidders have confidence in the procurement procedures for soliciting and awarding contracts, it is the policy of the City to offer Bidders the opportunity to appeal award of contracts. The following procedures shall apply in regard to appeals:
1. Any actual Bidder who is aggrieved in connection with this RFB or award of a contract hereunder may protest to the City of Visalia Purchasing Division in writing within five (5) working days after such aggrieved Bidder knows, should have reasonably known, or could reasonably be expected to know of the facts giving rise thereto; and
2. Should identify only the areas regarding bid contradictions, procurement errors, quotation rating discrepancies, legality of procurement context, conflict of interest in the rating process, and inappropriate or unfair competitive procurement grievance regarding the Bid process.
3. The City’s Purchasing Division shall have the authority to settle and resolve each protest. The resolution will be provided to Bidder in writing within five (5) working days of receipt of the appeal, unless the Bidder is notified that more time is required.
4. Further levels of appeal may be made in accordance with the appeals provision contained in Chapter 5 of the City’s “Purchasing and Contract Procedures,” which is available through the City’s Purchasing Division.
X. SPECIAL CONDITIONS
1. Project Administrative Issues
a. Complete Project. The successful Bidder shall be responsible for providing all materials, labor, equipment, and services necessary to fulfill the requirements of this RFB.
b. Quantities/Change Orders. The City reserves and shall have the right to make such changes to the work as may be necessary and desirable to complete the work originally intended in an acceptable manner. Unless otherwise specified herein, the Project Manager shall be and is hereby authorized to make such changes in the work as may increase or decrease the originally awarded contract quantities and/or total contract cost. The Contract Price, or the amount due the Contractor, will only be reduced/increased after the price change is reviewed and authorized by the City of Visalia Change Order Committee.
1005
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
Should the Contractor disagree with any terms or conditions set forth in an approved contract change order not executed by the Contractor, the Contractor shall submit a written protest to the Engineer within 15 days after the receipt of the approved contract change order, and the procedures outlined in Section 4-1.03 of the Standard Specifications apply.
If a requested change order is sent back to the Contractor for revisions, the Contractor has 15 (fifteen) calendar days to resubmit.
Changes shall not invalidate the contract nor release the surety, and the Contractor agrees to accept payment for such changes as if the altered work had been a part of the original contract. These changes, which are for work within the general scope of the contract, shall be covered by Change Orders issued by the City. Change orders for altered work shall include extensions of contract time where, in the Project Manager’s opinion, such extensions are commensurate with the amount and difficulty of added work.
Excessive altered work shall be covered by a supplemental agreement that is subject to funding agency approval, as applicable. If the City and the Contractor are unable to agree on a unit adjustment for any contract item that requires a supplemental agreement, the City reserves the right to terminate the contract with respect to the item and to make other arrangements for its completion.
c. Omitted Items. The Project Manager is authorized to omit minor contract items. Major items must be omitted by supplemental agreement.
d. Extra Work. Contractor is prohibited from doing extra work, unless authorized in writing by the Project Manager before the work is done. The Project Manager should obtain authorization from the Change Order Committee before agreeing to extra work requested by the Contractor. In the instances where it is necessary for the work to be done immediately, the Project Manager may authorize the work prior to taking the additions to the Change Order Committee. Payment for approved Extra Work shall be as agreed to in writing by the Project Manager prior to the Extra Work being completed, or the Change Order Committee shall approve an increase in a Change Order issued after the Extra Work is completed. No additional payment is due for unauthorized Extra Work.
If the Project Manager authorizes Extra Work but the payment for the Extra Work has not been agreed to in writing prior to the work being completed, then Contractor shall submit to the Project Manager the documentation required for a Change Order within forty-five (45) days of completing the Extra Work. The Project Manager will submit a Change Order request for review and approval by the Change Order Committee. If the Contractor does not submit any documentation within that time period, the Project Manager may move forward with issuing a Change Order to adjust the contract price. e. Removal of Obstructions. Contractor shall remove and dispose of all structures, debris, or other obstructions of any character required for completion of the project. Any temporarily removed or relocated items shall be replaced. f. Clean Up. Prior to acceptance and final payment, Contractor shall clean up the site of work and any areas occupied by Contractor in connection with the project.
2. City-Contractor Relations
a. Project Manager’s Responsibility and Authority. City will designate a Project Manager.
All work shall be done under the general supervision of such Project Manager or his or her designee(s). The Project Manager shall decide issues of quality and acceptability of materials, work performance, rate of progress of work, interpretation of drawings and specifications, and all questions related to fulfillment of the contract for the project. 1006
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
Project Manager shall not have control over acts or omissions of the Contractor, Subcontractors, their agents, or employees.
b. Contractor/Contractor’s Superintendent. Contractor shall bear all responsibility for, and have all control over, the construction means, methods, techniques, sequences, procedures, and safety precautions or programs related to the project. Contractor may designate a superintendent.
c. Project Site/Existing Utilities and Structures.
(1) Contractor shall take care to avoid, but shall be responsible for, all damage to existing structures, including, but not limited to, sewers, water service, drains and culverts, underground utilities, and the like.
(2) USA Notification. Contractor shall notify underground service alert (“USA) of times and locations of proposed excavations.
i. Contractor shall notify owners of and be responsible for damage to utilities and substructures.
ii. If damage occurs to an unknown utility, Contractor shall repair the utility.
iii. Contractor shall not make a connection to or draw water from any hydrant or pipeline without first obtaining permission to do so. d. Signs, Barricades, and Notice. Contractor must provide and maintain proper barricades, fences, signal lights, watchmen, and notice in general to the surrounding public, in accordance with local, federal, and state requirements. e. Labor
(1) Workmanship. Workmanship shall be equal to the best general practice of modern-day landscaping and irrigation repair practice.
(2) Qualification. Contractor shall ensure that each employee who works on this project is qualified to perform their assigned duty in a safe manner. f. Control of Materials:
(1) Source of Supply and Quality of Materials Guarantee. All materials, parts, and equipment supplied by the Contractor shall be new and of a quality equal to that specified. Materials that become unfit for use shall not be used for the project.
(2) Equivalent Materials. Trade names or manufacturer’s catalog information, where used, are a means of indicating kind, type, design, style, finish, durability, or quality desired and are not intended to exclude or omit the products of any responsible manufacturer, if such products are equal in every respect to those specified. The burden of proof of compliance with the specifications is the responsibility of the Contractor. City shall be the sole judge as to the adequacy of any item for substitution.
(3) Manufacturer’s Directions. Manufactured articles, materials, and equipment shall be applied, installed, connected, erected, used, cleaned, and conditioned as directed by the manufacturer.
g. Storage of Materials. Materials shall be stored to ensure the preservation of their quality and fitness for the project.
h. Materials and Shop Drawing Submittals. If applicable, Contractor shall submit to Project Manager for approval, two (2) copies of the materials list and detailed dimensional shop drawings covering all Contractor-furnished items of equipment. Prior approval by the Project Manager is required. Such approval shall not relieve the Contractor from the responsibility of deviation from the Contract unless Contractor has, in writing, called to the attention of the Project Manager such deviations. 1007
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
3. Legal Responsibilities. It is the responsibility of Contractor to comply with all local, state, and federal laws and regulations that apply to this project. This includes, but is not limited to, compliance with Uniform Building, Plumbing, Mechanical, Electric, and Fire Codes. Contractor shall provide a safe working environment in compliance with the Occupational Safety and Health Act and California Health and Safety Codes. Additionally, Contractor shall secure all necessary permits, licenses, and similar requirements to carry out the project. Contractor shall comply with all applicable labor laws and ensure against discrimination.
XI. GENERAL CONDITIONS
1. It is the policy of the City to provide equal opportunity to all candidates when selecting Bidders to provide public services. Bidders are expected to be equal opportunity employers.
The City hereby affirmatively ensures that Disadvantaged Business Enterprises (DBE) will be afforded full opportunity to submit a Bid in response to this notice and will not be discriminated against on the basis of race, color, national origin, ancestry, disability, gender, or religion in any consideration leading to the award of contract.
No qualified disabled person shall, on the basis of disability, be excluded from participating in, be denied the benefits of, or otherwise be subjected to discrimination under any program or activity that receives or benefits from Federal financial assistance.
Bidder shall provide to the City a list of all instances within the last ten (10) years where a complaint was filed or pending against Bidder in a legal or administrative proceeding alleging that Bidder discriminated against its employees, subcontractors, vendors, or suppliers. A description of the status or resolution of that complaint, including any remedial action taken, is required.
2. Post-Closing Date Corrections are prohibited.
3. Bids will not be accepted unless signed in ink (not typed) in the appropriate space(s) by an authorized officer or employee of the Bidder.
4. Bids must be submitted on or before the Closing Date. Any Bids received after the Closing Date shall be returned, unopened, to the Bidder, provided the request number, opening date, and Bidder's return address are on the envelope.
5. Bids may be withdrawn prior to the Bid Closing Date by writing to the Purchasing Division.
6. Telegraphic, telephonic, electronic, and facsimile Bids and withdrawal requests will not be accepted.
7. Prices submitted are considered accurate for a period of ninety (90) days and cannot be withdrawn after the Closing Date.
8. All Bids are the property of the City after submission.
9. City is not responsible for Bid errors and omissions.
10. Bids should be prepared in a straightforward, concise manner. Information provided that was not specifically requested will be considered only at the City’s discretion.
11. A written amendment or addenda issued by City’s Purchasing Division is the only method that should be relied on with respect to changes to the RFB. Respondent is responsible for contacting the City’s Purchasing Division prior to submitting a Bid to determine if any amendments were made to the RFB.
12. Any contract resulting from the RFB will be jointly administered by the City’s Purchasing Division and the Department requesting Bids.
1008
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
13. Prior to conducting business in the City, a business tax certificate (license) must be obtained.
Call 559-713-4326 for more information.
14. Bidder shall provide insurance as required by law and as indicated in the proposed contract.
15. Bidder shall maintain all personnel files and payroll records for employees used to implement the proposed contract.
16. Bidder shall withhold, pay, and report all taxes and issue W-2 forms at the end of each calendar year for employees used to implement the proposed contract.
17. Pursuant to the City’s Charter, all other things being equal, tie Bids shall be awarded to a local merchant to the extent quality and prices are equal. If neither is a local vendor, the Bid shall be awarded by the flip of a coin by the Purchasing Division in the presence of at least one witness.
18. The City may make such investigation of the Bidder and information in the Bid as it determines necessary. This may include the collection of criminal history information, contractual and business associations and practices, employment histories, and reputation.
19. All California agencies may purchase off the Proposal submitted at the same prices, terms, conditions, and specifications. The City of Visalia shall incur no responsibility in connection with another agency’s purchase.
20. Each Bidder will be required to submit Certifications, Affidavits, Assurances, Statements, and Questionnaires, which are attached in Exhibit “B”.
21. The quantities given on the Bid Proposal form and any related contract documents are approximate only. They are given as a basis for comparison of Bids. The City of Visalia does not, expressly or impliedly, agree that the actual amount of work will correspond therewith, but reserves the right to increase or decrease the amount of any class or portion of work, or to omit a portion of the work, as the City deems necessary or advisable, at the prices Bid.
22. Bidders shall satisfy themselves by personal examination of the work site, specifications, plans, and other contract documents, and by any other means as they believe necessary, as to the actual physical conditions, requirements, and difficulties under which the project must be performed. The submission of a Bid shall be conclusive evidence that the Bidder has investigated, and is satisfied as to the conditions encountered, as to the character, quality, and quantities of work to be performed, and the materials to be furnished, and as to the requirements of the RFB and the City. No allowance shall subsequently be made because of a lack of such examination or knowledge.
23. All Bidders are required to make a Bid on the complete Bid Form (Exhibit “A”). Contractor may be required to submit Proposals on alternate items. The City reserves the right to award the contract based on the lowest combination or combinations of Proposal items and alternate proposed items.
24. No mention shall be made in the Proposal of sales tax, use tax or any other tax, as all amounts Bid will be deemed and held to include any such taxes, which may be applicable.
25. Only one Bid may be submitted as a “Prime Contractor” for the same work by any firm, individual, partnership, corporation, or combination thereof. A Contractor submitting a Bid as a Prime Contractor may not also submit sub-Bids to other competing Prime Contractors.
Reasonable grounds for believing that any individual, firm, partnership, corporation, or combination thereof is interested in more than one Proposal for the work contemplated will cause the rejection of all Proposals in which such individual, firm, partnership, corporation, or combination thereof is interested. A Contractor who is not submitting a Bid as a Prime Contractor may submit any number of sub-Bids to competing Prime Contractors. 1009
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
26. The City of Visalia is not liable for any costs incurred by Bidder in responding to this Request for Bid.
27. The annual contract resulting from this invitation to bid will be administered by the Public Works Department. However, the city's Purchasing Division shall be the final judge concerning issues or matters related to contract interpretation or problems regarding the terms, conditions, or scope of the contract.
28. The initial contract term shall be for a twelve (12) month period and shall, at the City’s option and with the consent of the CONTRACTOR, be extended annually thereafter for four (4) consecutive one-year periods. Contract shall begin no later than 15 days from the receipt of the annual contract.
29. All prices quoted in response to this Invitation to Bid shall be firm and fixed for twelve (12) months from the annual anniversary date of the agreement. In order to protect the interests of the City and to give the vendor a reasonable basis for bidding, a price adjustment feature is hereby incorporated into the specifications. Prices bid by the vendor may be adjusted annually at the time of contract renewal and upon mutual agreement of the parties to the contract to allow for price increases or decreases for labor and benefit rates, supplies and materials.
It will be the responsibility of the contractor to request a price adjustment and to provide all documentation necessary. The request for price adjustment must be submitted to the project manager in writing, a minimum of thirty (30) but no sooner than ninety (90) calendar days prior to the annual anniversary date of the agreement. Requests filed after this time period will not be considered.
The unit prices for the ensuing contracts shall be based on the movement of the unadjusted figures of the U.S. Bureau of Labor Statistics, Consumer Price Index (CPI) for all Urban Consumers (CPI-U U.S. City Average, All Items). The contract unit prices may be changed in an amount equal to the percentage of movement for the most recent twelve-month period closest to the anniversary month of contract. In no instance shall the price increase exceed 5%.
The contract unit price changes as a result of this formula shall be binding on the contractor for the subsequent contract year. The adjustment of the unit bid price shall not be retroactive and shall apply only to changes incurred after approval.
30. This contract may be terminated without cause by the City, in whole or in part, by giving the Contractor fifteen (15) days written notice of the intent to terminate whenever the City determines that termination is in the best interest of the City.
If the Contractor shall fail to provide services or perform satisfactorily the work required by the terms and conditions of the contract, or materially breaches any of its obligations under this agreement, the City may terminate the contract, in whole or in part, by written notice.
Termination shall take effect ten (10) calendar days after the date of mailing said termination notice.
Any assignment, subletting, or transfer of the interest of the contractor, either in whole or in part, without the written consent of the City, shall be cause for the City to immediately terminate the agreement for default.
Notwithstanding any other provisions of this agreement, this agreement may be terminated by the City upon a single violation of this agreement.
XII. POST AWARD RESPONSIBILITIES
1. Written Contract with City. A written agreement in a form similar to that attached to this Request for Bid as Exhibit “C” with Attachments 1-2 must be entered into between the City and the Contractor to whom the project is awarded. The Agreement forms the basis for the contractual obligation between the parties regarding the project. A contract will be provided with the Notice of Award and must be executed and returned to the City within ten (10) working days of the date of award notification unless otherwise agreed. 1010
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
2. Post-Award Responsibilities. Upon execution of the Agreement between the City and the Contractor, the Contractor shall immediately report all changes in its Articles of Incorporation, By-Laws, or Tax-Exempt status to the City.
3. Insurance. Contractor shall obtain and maintain the minimum insurance coverage outlined Exhibit “C”, Attachment 2. Contractor shall provide evidence of such insurance to City’s Purchasing Division prior to commencement of work.
Upon determination by the City that a contract has been entered into and Contractor has provided all of the information that it is required to provide pursuant to this RFB, City will issue, in writing, a notice to proceed on the project to Contractor.
1011
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
Bidding Firm:_____________________
EXHIBIT “A”
BID FORM
RFB NO. 25-26-48
Project: ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES TO: THE CITY OF VISALIA PURCHASING DIVISION:
In compliance with the City’s Notice Inviting Sealed Bids No. 25-26-48 dated: __________, the undersigned BIDDER hereby proposes to furnish all materials, equipment, tools, labor appurtenances and incidentals required for the above stated project as set forth in the RFB, including all Exhibits and related contract documents therefore, and to perform all work in the manner and time prescribed therein.
BIDDER declares that this proposal is based upon careful examination of the scope of services , Instructions to BIDDERs, and the contract requirements. If this proposal is accepted for award, BIDDER agrees to enter into a contract with CITY at the unit and/or lump sum prices set forth in the following Bid Schedule.
BIDDER understands that a bid is required for the entire work and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. It is agreed that all prices bid include all appurtenant expenses, taxes, royalties, and fees. All bids will be checked for accuracy. In the case of discrepancies in amounts bid, unit prices shall govern over extended amounts.
BIDDER hereby agrees to execute a contract within ten (10) working days, or such further time as may be allowed in writing by the Purchasing Division, after receiving notification of the acceptance of this Bid, and it is hereby mutually understood and agreed that in case the BIDDER does not, said Purchasing Division may proceed to award the contract to others.
BIDDER agrees to commence the work on the start date agreed between BIDDER and Project Manager, only after the contract is fully executed and Notice to Proceed has been issued.
BIDDER further declares that he/she has not either directly or indirectly entered into any agreement, participated in any collusion, or otherwise taken any action in restraint of free competitive bidding in connection with said bid.
Bid Award shall be based on the Total Bid Amount. The quantities given on the Bid Proposal form and any related contract documents are estimates only. They are given as a basis for comparison of Bids. The City of Visalia does not, expressly or impliedly, agree that the actual amount of work will correspond therewith, and reserves the right to increase or decrease the amount of any class or portion of work, or to omit a portion of the work, as the City deems necessary or advisable, at the prices Bid.
BIDDER has read and hereby agrees to the conditions stated in this proposal by affixing his/her signature on the Bid Form.
In the case of discrepancy in amounts bid, unit pricing shall prevail over extended amounts. 1012
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
Bidding Firm: _____________________
As specified in RFB-25-26-48 and Exhibits. Prices shall reflect all required service frequencies and schedules outlined in the RFB and shall include all labor, equipment, fuel, supplies, and all services necessary to perform the work fully. The quantities and service frequencies provided are estimates only and are not guaranteed. The City reserves the right to increase or decrease service levels as needed.
Item 1: Mowing Services Square
Footage
Unit
Price
Per
Service
Estimated
Number of
Services
Annually
Annual Cost
Parks/Locations Serviced Weekly
March through October: once per Week
November through February: every other week
1,508,301 44
$
Riverway Sports Park Mowing Serviced Weekly
(Exhibits D-1 & D-3)
* March through November: once per week
* December through February: every other week
1,996,813 45
$
Riverway Sports Park Mowing – Enhanced Service
Schedule (Exhibits D-1 & D-3)
* March: once per week
* April through October: twice per week
* November through February: twice per month
1,996,813 72
$
Item 1: Total Annual Cost $_________
*Bidders shall provide pricing for both the standard weekly and enhanced mowing service schedule options for Riverway Sports Park as outlined in the Bid Form.
Item 2: Aeration Services Cost Per Acre
Estimated
Acres
Serviced
Annually
Annual
Cost
Whitendale Park (4 acres)
Jefferson Park Softball Fields (2 acres)
Fairview Park (13 acres)
Plaza Park Softball Fields No. 1–4 (8 acres)
3 services annually (May, July, September)
Aerate, mulch cores, no sand $
81 $
Riverway Sports Park – Common Areas (23 acres)
1 service annually (May)
Aerate, mulch cores, no sand $
23 $
Riverway Sports Park – Soccer Fields (19 acres)
1 service annually (May)
Aerate, core removal, and apply sand $
19 $
Riverway Sports Park – Soccer Fields (19 acres)
2 services annually (July & September)
Aerate, core process or removal, no sand $
38 $
Riverway Sports Park – Baseball & Softball Outfields (9 acres)
3 services annually (May, July, September)
Aerate, core process or removal, no sand $
27 $
Item 2: Total Annual Cost $_________
1013
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
Bidding Firm_________________
Item 3: Scalping Services (as specified in Exhibits) Price per Service
Estimated
Number of
Services
Annually
Annual
Cost
Riverway Sports Park – Soccer Fields (19 acres)
2 services annually (May & October)
Scalp to 1.5 inches; vacuum all clippings $
2 $
Item 3: Total Annual Cost $________
TOTAL BID SUMMARY Total Annual Cost
Item 1: Mowing Services $
Item 2: Aeration Services $
Item 3: Scalping Services $
TOTAL BID AMOUNT
(Total Annual Cost) $______________
BIDDER’S UNIT PRICES – As new parks are completed in the city and/or new areas are designated for mowing or aeration, they will be added to the existing contract at the same rates as the original routes based on the unit prices provided herein.
UNIT PRICES FOR MOWING AND
AERATION
Item
Unit Cost
(weekly service)
Unit Cost
(twice weekly service)
Turf – maintained as specified in RFB $______________/per sq. ft. $____________/per sq. ft.
Unit Cost per Acre
Aeration, core process or removal, No Sand $______________/per acre Aeration, core removal, with Sand Application $ /per acre Aeration, Mulch Cores, No Sand $______________/per acre Scalping, vacuum clippings, or removal $______________/per acre Contractor’s Hourly Labor Rate
Contractor’s Hourly Labor Rate for Additional Services (applicable only when authorized by City’s Project Manager or Recreation Manager) for misc. lawn maintenance. services, one-time clean-ups, and irrigation repairs on city property. This rate will also be used for misc. field preparation services for Softball Tournaments at Plaza Park. $______________/per hour
1014
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
By signing below, the Bidder certifies that all required licenses are current, active, and in good standing with the California Contractors State License Board (CSLB), and that all work performed under this contract will be completed by properly licensed individuals or subcontractors in accordance with applicable laws. (1)_____________________________________________________________________________________ Bidding Firm
(2)_____________________________________________________________________________________ Corporation, Partner, Joint Venture
(3)_____________________________________________________________________________________ Business Address City State Zip Code
_________________________________________________________________________________________ Telephone Number Fax Number
_________________________________________________________________________________________ E-mail Address
(4)_______________________________________________________________________________________ Signature of Authorized Person (Date)
________________________________________________________________________________ Type or Print Authorized Person’s Name
PLEASE SEE THE FOLLOWING INSTRUCTIONS REGARDING SIGNATURE (1) If the BIDDER is an individual, enter name here in style used in business; if a joint venture, exact name of entities joining in the venture; if a partnership, the correct trade style of the partnership; if a corporation, the exact name of the corporation.
(2) If BIDDER is other than an individual, identify here its character, i.e., joint venture, partnership, corporation, including the state of incorporation. If BIDDER is an individual operating under a trade name, state “an individual dba (trade name in full)”.
(3) State on this line the address to which all communications and notices regarding the Bid Proposal, and any contract awarded thereunder, are to be addressed.
(4) If BIDDER is a joint venture, signature must be by one of the joint venturers, and if one or both of the joint venturers is a partnership or a corporation, each participating partnership must sign by a general partner, and each corporation by an authorized officer or employee; if a partnership, by a general partner; if a corporation, by an authorized officer or employee. The title of the person signing must appear after his/her signature. Where BIDDER is a partnership or corporation, the names of all other general partners, or the president or secretary of the corporation, and their business addresses must be shown below.
Note: All names must be typewritten under the written signature. All Addresses must be complete with street number, city, state, and zip code.
1015
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
BIDDING FIRM:_______________________________
BIDDING CONTRACTOR’S LICENSE INFORMATION:
STATE CONTRACTOR’S LIC. CLASS:_________________ # _____________________________ EXP. DATE:___________
STATE D.I.R. REGISTRATION #______________________________________________________ FEDERAL TAX I.D. #______________________________________ CITY OF VISALIA BUSINESS TAX CERTIFICATE #__________________________________(A City Business Tax Certificate (license) is not required to submit a bid; however, vendor is required to obtain a City License prior to commencement of work or if vendor is presently transacting business within the City of Visalia, regardless of whether the business address is actually located within the City. Contact the Business License Division for clarification of questions at 559-713-4326.
CONTRACTOR’S REFERENCES: The following are the names, addresses, and telephone numbers for at least three (3) public agencies for which BIDDER has performed work similar in size and scope within the past five (5) years.
REFERENCE 1
NAME OF AGENCY:____________________________CONTACT PERSON:_________________________ AGENCY ADDRESS:____________________________PHONE #:__________________________________ REFERENCE 2
NAME OF AGENCY:____________________________CONTACT PERSON:_________________________ AGENCY ADDRESS:____________________________PHONE #:__________________________________ REFERENCE 3
NAME OF AGENCY:____________________________CONTACT PERSON:_________________________ AGENCY ADDRESS:____________________________PHONE #:__________________________________
DESIGNATION OF SURETIES
The following are the names, addresses, and telephone numbers for all brokers and sureties from whom BIDDER intends to procure insurance.
COMPANY NAME:_______________________________TYPE OF INSURANCE:_______________________ ADDRESS:_____________________________________TELEPHONE#______________________________ COMPANY NAME:_______________________________TYPE OF INSURANCE:_______________________ ADDRESS:_____________________________________TELEPHONE#______________________________ COMPANY NAME:_______________________________TYPE OF INSURANCE:_______________________ 1016
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
ADDRESS:_____________________________________TELEPHONE#______________________________ BIDDING FIRM:_______________________________
SUBCONTRACTOR LISTING
The undersigned hereby designates below for the project, opposite various portions of the work, the names and locations of the places of business of each subcontractor who will perform work or labor in an amount in excess of one-half of one percent (1/2 of 1%) of the total bid. All work not listed below shall be performed by the undersigned BIDDER. It is understood that the BIDDER, if awarded the contract, shall not substitute any subcontractor in place of the subcontractors herein designated without the approval of the Project Manager.
SUBCONTRACTOR INFORMATION & TRADE CLASSIFICATION (CIRCLE ALL THAT APPLY)
1. Subcontractor
Name:
Performing
_____% of
project work
Asbestos
Boilermaker
Bricklayers
Carpenters
Carpet/Linoleum
Cement Mason
Drywall Finisher
Drywall/Lathers
Electricians
Elevator Mechanic
Glaziers
Iron Worker
Laborers
Millwrights
Operating
Engineers
Painters
Pile Drivers
Pipe Trades
Plasterers
Roofers
Sheet Metal
Sound/Comm
Surveyors
Teamster
Tile Worker
Other:_________
Business Address:
Email Address:
CSLB # Expires:
DIR Registration #
2. Subcontractor
Name:
Performing
_____% of
project work
Asbestos
Boilermaker
Bricklayers
Carpenters
Carpet/Linoleum
Cement Mason
Drywall Finisher
Drywall/Lathers
Electricians
Elevator Mechanic
Glaziers
Iron Worker
Laborers
Millwrights
Operating
Engineers
Painters
Pile Drivers
Pipe Trades
Plasterers
Roofers
Sheet Metal
Sound/Comm
Surveyors
Teamster
Tile Worker
Other:_________
Business Address:
Email Address:
CSLB # Expires:
DIR Registration #
3. Subcontractor
Name:
Performing
_____% of
project work
Asbestos
Boilermaker
Bricklayers
Carpenters
Carpet/Linoleum
Cement Mason
Drywall Finisher
Drywall/Lathers
Electricians
Elevator Mechanic
Glaziers
Iron Worker
Laborers
Millwrights
Operating
Engineers
Painters
Pile Drivers
Pipe Trades
Plasterers
Roofers
Sheet Metal
Sound/Comm
Surveyors
Teamster
Tile Worker
Other:_________
Business Address:
Email Address:
CSLB # Expires:
DIR Registration #
1017
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES
BIDDING FIRM:_______________________________
4. Subcontractor
Name:
Performing
_____% of
project work
Asbestos
Boilermaker
Bricklayers
Carpenters
Carpet/Linoleum
Cement Mason
Drywall Finisher
Drywall/Lathers
Electricians
Elevator Mechanic
Glaziers
Iron Worker
Laborers
Millwrights
Operating
Engineers
Painters
Pile Drivers
Pipe Trades
Plasterers
Roofers
Sheet Metal
Sound/Comm
Surveyors
Teamster
Tile Worker
Other:_________
Business Address:
Email Address:
CSLB # Expires:
DIR Registration #
5. Subcontractor
Name:
Performing
_____% of
project work
Asbestos
Boilermaker
Bricklayers
Carpenters
Carpet/Linoleum
Cement Mason
Drywall Finisher
Drywall/Lathers
Electricians
Elevator Mechanic
Glaziers
Iron Worker
Laborers
Millwrights
Operating
Engineers
Painters
Pile Drivers
Pipe Trades
Plasterers
Roofers
Sheet Metal
Sound/Comm
Surveyors
Teamster
Tile Worker
Other:_________
Business Address:
Email Address:
CSLB # Expires:
DIR Registration #
6. Subcontractor
Name:
Performing
_____% of
project work
Asbestos
Boilermaker
Bricklayers
Carpenters
Carpet/Linoleum
Cement Mason
Drywall Finisher
Drywall/Lathers
Electricians
Elevator Mechanic
Glaziers
Iron Worker
Laborers
Millwrights
Operating
Engineers
Painters
Pile Drivers
Pipe Trades
Plasterers
Roofers
Sheet Metal
Sound/Comm
Surveyors
Teamster
Tile Worker
Other:_________
Business Address:
Email Address:
CSLB # Expires:
DIR Registration #
If more space is needed to list additional subcontractors and trade classifications, please list the remaining subcontractors on a separate sheet of paper (providing all of the requested information for each subcontractor) and submit with the bid.
1018
RFB NO. 25-26-48
ANNUAL CONTRACT FOR SPORTS PARK MOWING AND AERATION SERVICES