cc 2022 AR 01/11 second amendment to contract with gq builders

ACTION:
____________________________
Clerk/Secretary
Department: Public Works Item No: C6
Prepared by: Joshua Sino Cruz, Management Analyst Meeting Date: January 11, 2022 Approved by:

Kuna Muthusamy, Director
Patrick Johnson, City Manager Agenda Location: Consent Calendar SUBJECT: SECOND AMENDMENT TO CONTRACT WITH GQ BUILDERS, INC.

RECOMMENDATION: Adopt City Council Resolution No. 2022- , approving the second amendment to the contract with GQ Builders, Inc. for the Moonlight Restrooms Renovation Project.

COUNCIL GOALS: Routine operational item not directly corresponding to a specific City Council goal.

PRIOR ACTION: On February 9, 2021, adopted City Council Resolution No. 2021-17, approving a contract with SD Remodeling, Inc. for Moonlight Restrooms Renovation Project (Vote: 5-0).

On November 12, 2019, adopted City Council Resolution No. 2019-149, amending Operating Budget for Fiscal Years 2019/20 and 2020/21 (Vote: 5-0).

STATEMENT ON THE SUBJECT: On November 12, 2019, the City Council approved and allocated $180,000 in year-end fund balance to upgrade the north-end restrooms at the Moonlight Amphitheatre (Moonlight). These restrooms serve as the primary restrooms onsite holding the largest capacity. At the present, the restrooms do not reflect the quality of the venue, the productions, or experiences for which the Moonlight is known. The 23 years of wear and tear on the restrooms have made it difficult to maintain and keep clean, resulting in complaints from our patrons.

In February 2021, the City entered into a construction contract with SD Remodeling, Inc. to complete the project in the amount of $133,700. To date there has been one contract amendment, which updated their business entity name to GQ Builders, Inc. (GQ) (Exhibit 4), and four change orders totaling $24,227.19, for a current contract total of $157,927.19. The change orders were primarily needed due to unforeseen circumstances, which included removal of rotted and damaged subfloors, plumbing repairs, and drywall replacement. Additional details concerning the change orders are included as Exhibit 5. The change orders were approved by the City Manager and are within the authorized contract contingency amount.

During construction, GQ and staff have identified various unanticipated work items that are necessary for the completion of the project. The items include repairs to drywall and increased cost of materials and supplies such as toilet partitions and lighting fixtures. The cost of the additional work items is $3,680.

This added cost is outside the City Manager’s authorization and requires City Council approval.

Additionally, staff is requesting the contract ceiling to be increased to $180,000 ($18,392.81 more than the current change orders) to cover any unanticipated costs. Sufficient funding was allocated has been allocated to the project.

AGENDA
REPORT

CITY COUNCIL

COMMUNITY DEVELOPMENT COMMISSION

SUCCESSOR AGENCY

BUENA SANITATION DISTRICT

JOINT POWERS FINANCING AUTHORITY
01/11/2022 C6 1 of 56
Approved above recommendation, adopted City Council Resolution No. 2022-3.

Vote: 5-0

MEETING DATE: January 11, 2022 PAGE 2
SUBJECT: SECOND AMENDMENT TO CONTRACT WITH GQ BUILDERS, INC.

Staff recommends approval of the second amendment to the contract with GQ for the moonlight Restrooms Renovation Project. The approval of the second amendment in the amount of $22,072.81 brings the total contract ceiling to $180,000. The project is anticipated to be completed prior to the 2022 Moonlight Summer Season.

FISCAL IMPACT: The cost of the original contract and previously approved change orders with GQ Builders, Inc. is $157,927.19. Approval of the current and any future change orders will change the contract ceiling amount to $180,000. Funds are available in the Non-Department Replacement Capital Year End Fund Balance account (No. 0010145.562000.YEFB) to fund the remainder of the project.

EXHIBITS:

1.City Council Resolution No. 2022- , approving the second amendment to the contract with GQ Builders, Inc. for the Moonlight Restrooms Renovation Project

2.Second Amendment to Contract with GQ Builders, Inc.

3.Contract with GQ Builders, Inc.

4.First Amendment to Contract with GQ Builders, Inc.

5. Change Orders and Cost Breakdown
01/11/2022 C6 2 of 56

00104556 2
RESOLUTION NO. 2022-

A RESOLUTION OF THE CITY COUNCIL OF THE CHARTERED CITY OF

VISTA, CALIFORNIA, APPROVING THE SECOND AMENDMENT TO THE CONTRACT WITH GQ BUILDERS, INC. FOR THE MOONLIGHT

RESTROOMS RENOVATION PROJECT
The City Council of the City of Vista does resolve as follows:

1.Findings. The City Council hereby finds and declares the following:

A.On February 9, 2021, the City of Vista entered into a contract with SD Remodeling, Inc. for the Moonlight Restrooms Renovation Project.

B.Effective as of July 6, 2021, the Contract was amended to update the name of the Contractor to GQ Builders, Inc., a California corporation.

C.Since the contract was approved, four construction change orders totaling $24,227.19 were approved by the City Manager.

D.The current contract ceiling with GQ Builders, Inc. is $157,927.19 and the City desires to amend the contract with GQ Builders, Inc. to increase the contract by $22,078.81 for a new contract ceiling of $180,000.

2.Action.

A.The Second Amendment to the contract between the City of Vista and GQ Builders, Inc. for the Moonlight Restrooms Renovation Project is approved, and the Mayor is authorized to execute the contract.

B.The City Manager is authorized to execute all change orders up to the new contract ceiling amount of $180,000.
[Continued on page 2.]
01/11/2022 C6 3 of 56
EXHIBIT 1

RESOLUTION NO. 2022-

CITY COUNCIL OF THE CHARTERED CITY OF VISTA
PAGE 2
00104556 200104556.DOCX

3.Adoption. PASSED AND ADOPTED at a meeting of the City Council of the City of Vista held on January 11, 2022, by the following vote:

AYES:

NOES:

ABSTAIN:

APPROVED AS TO FORM:

DAROLD PIEPER, CITY ATTORNEY
By:

APPROVED
Darold Pieper
20211223151905

JUDY RITTER, MAYOR
ATTEST:

KATHY VALDEZ, CITY CLERK
By:
01/11/2022 C6 4 of 56

00104553 2

SECOND AMENDMENT TO THE CONTRACT BETWEEN THE CITY OF VISTA AND GQ BUILDERS, INC. FOR THE MOONLIGHT RESTROOMS

RENOVATION PROJECT
THIS SECOND AMENDMENT (“Second Amendment”) to the Contract between the City of Vista and GQ Builders, Inc., dated February 9, 2021 (“Contract”), is made and entered into as of _______________________ (“Second Amendment Date”), by and between the City of Vista, a chartered municipal corporation (“City”), and GQ Builders, Inc., a California corporation (“Contractor”).

Recitals: City, District, and Contractor now desire to enter into a Second Amendment to the Contract by modifying the terms of the Contract.

NOW, THEREFORE, in consideration of these recitals and the mutual covenants contained herein, City and Contractor agree as follows:

1.The Contract is amended to increase the contract ceiling by $22,072.81 to a new total contract ceiling of $180,000.00, to compensate Contractor for change orders associated with the Moonlight Restrooms Renovation Project.

2.All other conditions of the Contract shall continue in full force and effect.

IN WITNESS WHEREOF, the parties have executed and entered into this Second Amendment as of the Second Amendment Date.

CITY OF VISTA, a chartered municipal
corporation
By:

JUDY RITTER, MAYOR
ATTEST:

KATHY VALDEZ, CITY CLERK
By:

APPROVED AS TO FORM:

DAROLD PIEPER, CITY ATTORNEY
By:

RISK MANAGEMENT REVIEW:

DOLORES GASCON, RISK MANAGER
By:

APPROVED
Darold Pieper
20211223151058
GQ BUILDERS, INC., a California
corporation
By:

NAME/Title
By:

NAME/Title
01/11/2022 C6 5 of 56EXHIBIT 2

CONTRACT TITLE: Moonlight Restrooms Renovation Project DATE:11/17/2021

PAYMENT ALLOWANCES/

CONTINGENCIES

1.General Contractor Material and Equipment
a.Attach itemized quantity and unit cost plus sales tax. b. Include information where derived, i.e., “Means Building Construction Cost Data” or other source mutually agreed to by all parties.$0.00

2.General Contractor Labor
Attach itemized hours and rates per certified payrolls, prevailing wage chart and PSA agreements. Rates shall only include a maximum of 15% for payroll burden plus actual costs for Workers’ Compensation Insurance. Payment for extra supervision will be paid when extra Work is done in a time period other than normal Working hours.
$0.00

3. Subtotal: Item #1 plus Item #2 $0.00

4.General Contractor’s Overhead, Profit, Supervision, Bond Fees (A maximum aggregate total of 16% of Item #3.)
This item is not allowed on Extended Overhead, Allowances, or Contractor Contingencies.

5. Total General Contractor: Item #3 plus Item #4 $0.00

6.Subcontractor Material and Equipment
a.Attach itemized quantity and unit cost plus sales tax. b. Include information where derived, i.e., “Means Building Construction Cost Data” or other source mutually agreed to by all parties.
$0.00

7.Subcontractor Labor
Attach itemized hours and rates per certified payrolls, prevailing wage chart, and PSA agreements. Rates shall only include a maximum of 15% for payroll burden plus actual costs for Workers’ Compensation Insurance. Payment for extra supervision will be paid when extra Work is done in a time period other than normal Working hours.
$0.00

8. Subtotal: Item #6 plus Item #7 $-

9.General Contractors’ Overhead, Supervision, Bond Fees and Profit for Subcontractor Work
(A maximum aggregate total of 11% of Item #8.)
This item is not allowed on Extended Overhead, Allowances, or Contractor Contingencies.
-

10.Subcontractor’s Overhead and Profit
Maximum aggregate total of 15% of Item #8. Not to be included for Work provided by Contractor. No sub-tier markups allowed. Attach signed Subcontractor documentation on Subcontractor letterhead.

This item is not allowed on Extended Overhead, Allowances, or Contractor Contingencies.
$-

11. Subtotal: Item #9 plus Item #10. $-
TOTAL: Item #5 plus Item #8 plus Item #11. $-

CALENDAR

DAYS CALENDAR DAYS
For Allowances and Contractor Contingencies specified in Section 01 21 00, the Contractor’s costs for supervision, overhead, profit, and bonds have been included in the Contract Sum.

Attachment 1A, Hourly Labor Rate Worksheet must accompany all change orders, allowances or contingencies.

EXTRA OR CREDIT CHANGE ORDERS WILL NOT BE CONSIDERED UNLESS THIS EXHIBIT IS COMPLETELY Cost summaries, breakdowns, back-up or requests shall not be based, in whole or in part, upon any methodology

EXTRA/ADDITIONAL/

DELETED WORK
$2,400.00
$-
$2,400.00
$360.00
ESTIMATED TIME: (Zero, unless indicated; “TBD” not allowed) $2,760.00
$-
$-
$-
$-
$-
ATTACHMENT 1
GQ Builders Inc
Price Increase for the Toilet Partitions
$-
$2,760.00
CP21-0935-23
Payment – Extra, Additional, Deleted Work, Allowances, or Contractor Contingencies CO 01 PCO 01
01/11/2022 C6 6 of 56

CONTRACT TITLE: Moonlight Restrooms Renovation Project DATE:12/20/2021

PAYMENT ALLOWANCES/

CONTINGENCIES

3. Subtotal: Item #1 plus Item #2 $0.00

5. Total General Contractor: Item #3 plus Item #4 $0.00

8. Subtotal: Item #6 plus Item #7 $-

This item is not allowed on Extended Overhead, Allowances, or Contractor Contingencies.
$-

11. Subtotal: Item #9 plus Item #10. $-
TOTAL: Item #5 plus Item #8 plus Item #11. $-

CALENDARD

AYS CALENDAR DAYS
For Allowances and Contractor Contingencies specified in Section 01 21 00, the Contractor’s costs for supervision, overhead, profit, and bonds have been included in the Contract Sum.

Attachment 1A, Hourly Labor Rate Worksheet must accompany all change orders, allowances or contingencies.

EXTRA OR CREDIT CHANGE ORDERS WILL NOT BE CONSIDERED UNLESS THIS EXHIBIT IS COMPLETELY FILLED Cost summaries, breakdowns, back-up or requests shall not be based, in whole or in part, upon any methodology (such as

EXTRA/ADDITIONAL/

DELETED WORK
$800.00
$-
$800.00
$120.00
ESTIMATED TIME: (Zero, unless indicated; “TBD” not allowed) $920.00
$-
$-
$-
$-
$-
ATTACHMENT 1
GQ Builders Inc
Electrical Subcontractor price encreased due to project got delays. $-
$920.00
CP21-0935-23
Payment – Extra, Additional, Deleted Work, Allowances, or Contractor Contingencies Change Order No. 07 Electrical Sub.
01/11/2022 C6 7 of 56

CONSTRUCTION CONTRACT
THIS CONTRACT is made and entered into as of RJK rWo , q , 2!-)? 1 Contract Date"), by and between the City of Vista, a chartered municip• I corporation Agency"), and SD Remodeling, Inc., a California corporation ("Contractor"). Agency and Contractor are sometimes individually referred to as a "Party" and collectively as "Parties." In consideration of the mutual covenants contained herein, Agency and Contractor agree as follows:

SECTION 1
The Contract Documents consisting of the PROJECT SPECIFICATIONS, comprised of the NOTICE INVITING BIDS, the INSTRUCTIONS TO BIDDERS, the accepted BID PROPOSAL; BID SCHEDULE; CONTRACTOR'S LICENSING STATEMENT; PROJECT REFERENCES; CONTRACTOR'S LIST OF SUBCONTRACTORS;; PUBLIC CONTRACT CODE STATEMENTS AND QUESTIONNAIRE; NON -COLLUSION AFFIDAVITS; the CONSTRUCTION CONTRACT,

CONTRACTOR'S CERTIFICATE, SUPPLEMENTARY GENERAL PROVISIONS, SUPPLEMENTARY TECHNICAL PROVISIONS, Special Provisions, Plans, Standard Plans and Specifications; together with all additions, deletions, modifications, appendices, and all addenda (No. 4), as prepared prior to the date of bid opening setting forth any modifications or interpretations of any said documents, are hereby incorporated in and made a part of this Contract as fully as if set forth herein.

SECTION 2
For and in consideration of the payments and agreements to be made and performed by the Agency as set forth in said Contract Documents, the Contractor agrees with the Agency to construct

MOONLIGHT RESTROOMS RENOVATION PROJECT
as specifically set forth in documents entitled

MOONLIGHT RESTROOMS RENOVATION PROJECT
for which award of the Contract was made, to furnish at his own proper cost and expense all plant, labor, services, materials, tools, equipment, supplies, transportation, utilities and all other items and facilities necessary therefore, as provided in the Contract Documents, and to do everything required therein. In accordance with the provisions of Section 3700 of the Labor Code, the Contractor will be required to secure the payment of Worker's Compensation Insurance for its employees.

SECTION 3
For furnishing all said services and materials, payment of premiums on insurance policies, obtaining all permits and licenses of a temporary nature, furnishing and removing all plant, temporary work or structures, tools, and equipment, and for doing all the Work contemplated and embraced in this Contract, also for all loss and damage arising out of the nature of the aforesaid work during its progress or prior to acceptance from the action of the elements and SUMMARY CONSTRUCTION - COV LOCAL Page 1 of 3 SD REMODELING, INC. 00064028-11 00094695 1
01/11/2022 C6 8 of 56EXHIBIT 3

SECTION 6
Contractor agrees that the Payment Bond and Performance Bond attached to/submitted concurrently with this Contract are for reference purposes only, and shall not be considered a part of this Contract. Contractor further agrees that said bonds are separate obligations of the Contractor and its surety, and that any attorneys' fee provision contained in any payment bond or performance bond shall not apply to this Contract. In the event there is any litigation between the Parties arising from the breach of this Contract, each Party will bear its own attorneys' fees in the litigation.

IN WITNESS WHEREOF, the Parties have caused this Contract to be executed as of the Contract Date.

CITY OF VISTA, a chartered municipal
corporation
By%q?Tmi
Jt! T ,MAYOR
ATTEST:

KATHY VALDEZ, CITY CLERK
By:

APPROVED AS TO FORM:

DAROLD BIQR, CITY UORNEY
By:

RISK MANAGEMENT REVIEW:

DOLORES GAscoN ISK MANAGER
r
By:

APPROVED
Darold Pieper
20210119111056
SUMMARY CONSTRUCTION — COV LOCAL Page 3 of 3
00064028-1] 00094695 1
SD REMODELING, INC, a California
corporati n
By=
OZY1_4 Awrodniv. GEQ
Name/Title
No
Name/Title
SD REMODELING, INC.
01/11/2022 C6 9 of 56

BID PROPOSAL
From: SO Remodeling-, Inc. - - - . Bidder,
For: The construction of

REAL PROPERTY IMPROVEMENTS
as specifically set forth in documents entitled

MOONLIGHT RESTROOMS RENOVATION
The undersigned hereby proposes and agrees that if his bid as submitted in the attached BID SCHEDULE be accepted, he will contract in the form so approved to perform all work for which a Contract may be awarded him, to furnish any and all plant, labor, services, materials, tools, equipment, supplies, transportation, utilities and all other items and facilities necessary therefore as provided in the Contract Documents, and to do everything required therein for the proposed Project as specifically set forth in said Contract Documents. together with appurtenances thereto, all as set forth on the Drawings and in the Project Specifications and other Contract Documents: and he further proposes and agrees to complete all the Work. called for by the Drawings, Project Specifications, and other Contract Documents in strict conformity therewith within the time limits set forth therein; and that he will accept as full payment therefore the prices set forth in the BID SCHEDULE forming a part hereof.

The undersigned hereby submits either a Bid Bond or Bid Security in the form of Cash, a Cashier's Check, or a Certified Check, using the forms Included in these Bid Documents, properly made payable to CITY OFViST& hereinafter designated as the Agency, In an amountthat is at leastten percent (10%) of the total base bid amount. The Bid Bond or Bid Security is attached hereto and is given as a guaranty that the undersigned will execute the Contract and furnish the required bonds if awarded the Contract and, in case of failure to do so within the time provided, the proceeds of said bond or bid security shall be forfeited to the Agency. The Surety's liability to the Agency for forfeiture of the face amount of the bond shall be considered as established.

OW
01/11/2022 C6 10 of 56

It is understood and agreed that:

1. The undersigned has carefully examined all Bid documents and other Documents which will form the Contract, Including all addenda as prepared prior to the date of bid opening setting forth any modifications or interpretations of any said documents.

2. The undersigned has, by investigating the site of work, by reviewing and analyzing the Plans and Specifications, and by otherwise familiarizing himself with the Project, has satisfied himself as to the nature and location of the Mork and has fully informed himself as to all conditions and matters which can in any way affect the Work or the cost thereof.

3. The undersigned fully understands the scope of the Work and has included in the various related items of Work the cost of all work not listed as a separate item so that the Sid for the Project reflects the total cost for completing the Work in its entirety; has checked carefully all words and figures inserted in this Bid, and he further agrees that the Agency shall In no way be responsible for any errors or omissions in the preparation of this proposal.

4. The undersigned will execute the Contract and furnish the required Performance Bond, Payment Bond, and proof of insurance coverage within the stipulated time after the posting of a notice to hire of acceptance of his bid by the Agency; and further, that this bid may not be withdrawn for a period of ninety (90) calendar days after the date set for the opening thereof unless otherwise required by law. If any bidder shall withdraw his bid within said period, the bidder shall be liable under the provisions of the Bid Security, or the bidder and his surety shall be liable under the Bid Bond, as the case may be.

5. The surety or sureties and insurance companies named in the space provided have agreed to furnish bonds, insurance, and endorsements in the form and amounts set forth in the Contract Documents in the event the Contract is awarded on the basis of this proposal.

6. The undersigned hereby certifies that this proposal is genuine and not sham or collusive or made in the interest or in behalf, of any person not herein named, and the undersigned has not directly or indirectly induced or solicited any other bidder to put in a sham bid, or any other person, firm or corporation to refrain from bidding, and the undersigned has not in any manner sought by collusion to secure for himself an advantage over any other bidder.

In conformance with current statutory requirements of Section 1860, et. seq., of the Labor Code of the State of California, the undersigned confirms the following as his certification:

I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers' compensation or to undertake self-insurance In accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract."

8. Receipt of Addenda No..L through _4_ is hereby acknowledged. (if none, write 'NONE'), 01/11/2022 C6 11 of 56

lD. |ncompliance with the Notice Inviting Bids and all the provisions heoa|nbufnr8stipulated, the Undmrsignod, with full cognizance thereof, hereby proposes to perform the entire work for the prices set forth in the attached BID SCHEDULE upon which award of the Contract is made. Continued on next page) 28
01/11/2022 C6 12 of 56

DATE: December 23rd 20 ,Q _ - -

CORPORATE SEAL)
Name and address of all members
of the firm or names of all officers
of the corporation.

Dmitriy Zagorodniy, CEO
BIDDER'S NAME SD Remodeling, Inc.

M
TITLE
Printed Name
BY
Signature
Printed Dame
TITLE
BIDDER'S MAILING ADDRESS:

P,O_ Box 1488
Rancho Santa Fe, CA 92067

CORPORATION ORGANIZED UNDER THE LAWS

OF THE STATE OF
California
CONTRACTOR'S LICENSE # 1024032
EXPIRATION DATE 02/28/2021

CONTRACTOR'S LICENSE CLASS B
SURETY OR SURETIES: C-SLB Surety Bond - Suretec
Insurance Company, SureBid Bond - The Ohio Casualty
Insurance Company INSURANCE
COMPANY: Workers
Comp - State Compensation Isurance Fund CAL -
Associated Idustries Insurance Co, Inc. I
certify (or declare) under penalty of perjury under the laws of the State of California that the foregoing is true and correct: 12/
23/2020 Date

C T OR'S SIGNATURE
01/11/2022 C6 13 of 56

BID SCHEDULE
Pursuant to and in compliance with the Notice Inviting Bids and other Contract Documents relating to the proposal for the construction of

REAL PROPERTY IMPROVEMENTS
as specifically set forth in documents entitled

MOONLIGHT RESTROOMS RENOVATION
all in accordance with the Plans and Project Specifications on 'le at the City of Vista Public Works Department, the undersigned bidder, having familiarized himself with the terms of the Contract, the local conditions affecting the performance of the Contract and the cost of the Work at the place the Work is to be done; and with the Plans, Project Specifications and other Contract Documents, hereby stipulated; the Contractor agrees to complete the Contract, including all of Its component parts and everything required to be performed, and to provide and furnish any and all labor, materials, tools, equipment expendable supplies and all utility and transportation services necessary to perform the Contract, and complete in a workmanlike manner all of the Work required in connection with the Contract, all in strict conformance with the Plans and Project Specifications on file at the City of Vista Public Works Department.

All items shall be finished and functional per Plans and the Contract Documents. Items designated with an 'S' in the Bid Item column of the Bid Schedule are Specialty Items per Subsection 2-3.2 ("Self Performance') of the Sap Diego Regional Supplement to the Greenbook.

Notes:
1) Please type or print legibly in spaces provided in the BID SCHEDULE. 21 Please do not use pencil.
31 Unit Prices shall be entered to two (2) decimal places only. 90 01/11/2022 C6 14 of 56

BID SCHEDULE
PROJECT NAME: MOONLIGHT RESTROOCvIS RENOVATION PROJECT

NAME OF BIDDER,
SD Remodeling, Inc.

Bid
Item
Description Of Work Qty. Unit Unit Price Item Total

GENERAL
MQ Jljzat on & Demobilization: Bid item shall
Include full compensation for all labor,
equipment and materials required to complete
all work required to mobilize all required
equipment, materials and personnel on -site,
and complete all associated and appurtenant
work in accordance with the Standard
Specifications, the Supplementary General
Provisions, and as directed by the Engineer.

The Bid Item shall also include all labor,
1 LS 4,000.00 4.000 00
equipment and material required to clean-up
and restore the site, demobilize and remove all
equlprnenti materials, and staging and
complete all work required at the end of
construction operations In accordance with the I
Standard Specifications, the Supplementary
General Provisions, and as directed by the
Engineer. The lump sum price for this item
shall not exceed 5% of the total contract price
5% maximum of Total Base Bid)
Materials: Bid Item shall include full r
compensation for all labor, equipment, shipping, 4fl4.00 transportation, and storing as well as, purchase
cost for all materials listed in Appendix B.

Installation Labor: Bid item shall include full
compensation for all labor, required to l
3 complete all work required in order to complete
105,300.00 ID5,300.00theprojectontime. This includes the labor costs of all subcontractors, laborers, and office
staff.
31 01/11/2022 C6 15 of 56

TOTAL BASE 9,4D FOR IMPROVEMENTS (in figures): $133, 700.00 One hundred thirty-three thousand seven hundred dollars and zero cents
NOTE: etermtnatlon of the lowest bld shall be based solely on the lowest, TOTAL 8115E BID FOR IMPROVEMENTS. unit prices shall prevall,ovef extended total and grand total prices. Late bids vAUnot be accepted.
32 01/11/2022 C6 16 of 56

CONTRACTOR'S LICENSING STATEMENT
The undersigned is licensed in accordance with the laws of the State of California providing for the registration of Contractors.

Contractor's license Number: 1024032
Contractor's License Class:

B
Expiration Date;
0212&/2021
As descrioed in the INSTRUCTIONS FOR SIGNING BIDS, BONDS AND CONTRACTS, complete and sign the appropriate section for your company)
Name of Individual Contractor (Print or type): NIA
Signature of Contractor:

Business Address:
or
Name of Partners#tio or loint Venture Firm:

NIA
Business Address:

Signature, printed name, title and address of members signing on behalf of the partnership:

Signature: Name: Title.

Address:

Signature:

Address:

NM
1411
Title:

Dame of Cornaratlon: SD Remodeling, Inc.

Business AddrM:
2055 Thibodo rd., Suite B. Vista, GA 92081
Corporation organized under the laws of the State of California tf Cal I ?
Signature o Fficer of Corporation Printed Nerve
and Title
33 01/11/2022 C6 17 of 56

Signature of Officer of Corporation
and Title
34 Printed Warne
01/11/2022 C6 18 of 56

PROJECT REFERENCES
The Bidder shall provide evidence that the Bidder has had the prior experience to property perform in accordance with the terms of these Plans and Project Specifications.

List A" contracts with public agencies entered within the past five (5) years of the most recent projects for which the Bidder has completed work of similar size and complexity to this project as the General (or Prime) Contractor, and the names and phone numbers of the contracting public agencies. Make copies of this page for listing additional projects.

Project j Date Completed
Public Agency Name, Project Name and Description Of
Contract Amount
No. f Contact Person b Phono w Work
L 09/21/2020 The Chicano Federation Chicano Federation Park Place 234,42p.00 of San Diego County Window Retrofit Project
Veronica Ruiz ADA ramp, railing, windows and
Ph: (619) 285-5600 blinds installation, hardware
installation

2. 09/18/2020 San Diego American ADA Site/Door HardwarefElevator S288,558.00 Indian Health Center Upgrades & HVAC Replacement
Kevin M. LaChapelle, Concrete, railing, hardware
Ph: (619) 234-51 f 2 installation, AC paving, striping, HVAC, elevator upgrades,
landscaping

3. 03110/2020 City of Chula Vista Norman Park Senior Center 511,160,00 Jerilyn Larson Restrooms and Kithens Ph. (619)
318-5723 Renovations and ADA Upgrades Plumbing, electrical, cabinetry, painting, flooring,
ADA ramp, drywall 4.
07/
18/2019 Department of Bathroom upgrades/repairs 8 272,500M Transportation HVAC installationlrepair Andrew Greiner
Plumbing, electrical, painting, Ph* (619)
718-7869 flooring, HVAC, doors and hardware Installation

5. 06/
08/2018 San Diego Community Avenza Center Remodel 78,800,00 College District Electrical, painting, door and Ramon Campos
hardware installalion, signage Ph: (619)
388-6819 6. 08/=
18/2017 Grossmont Union High Dystricwde Hydration Stations 98,000.00 School District Plumbing, stucco, painting Sylvia Sposato
Ph: (619)
590-3935 7. 12119/
2016 Sweetwater Union High HTH Title Ix - Girls Team Room 55,600.00 School District Trent Carr Painting, tlooring, signage, Ph: (
619)4074973 Note: Attached fire -
printed list to
this page to list additional projects. 35
01/11/2022 C6 19 of 56

CONTRACTOR'S LIST OF SUBCONTRACTORS
PROJECT NAME: MOONLIGHT RESTROOMS RENOVATION PROJECT
NAME OF BIDDER:

SD Remodeling, Inc.
1 ..i t t '•.1 i•a ` i ' .rl - 1- tl• a . !•. all 1 i a I !!! i1 i^
Subcontractors listed must be properly licensed for the type of work they are to perform, and their license numbers must be indicated below. Do not list alternate subcontractors for the same work.

Name under whIc h
Subcontractor Is Ilcensed
Umnse No.
and Gass
Address of Office,
Mill or Shop
OBE
Yes/No)
Bld
Item
No(s).

DoscdpUon of
Subcontractor's
Portion of Work
Dollar Value
of
Subcontract
Wakeland Electric, Inc. 1063245
C-10
18510 Pasadena S1,
Ste G,
Lake Elsinore, CA
92530
No 2,3 Electrical 4,500. 00
Provide additional copies of this sheet if needed)
KI
01/11/2022 C6 20 of 56

37 01/11/2022 C6 21 of 56

NON -COLLUSION DECLARATION

MOONLIGHT RESTROOMS RENOVATION PROJECT

TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID
The undersigned declares:

I am the CEO
Title)
of SO Remodeling, Inc. , the party making the foregoing bid.

Company Name)
The bid is not made In the interest of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation. The bid is genuine and not collusive or sham. The bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid. The bidder has not directly or Indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or to refrain from bidding. The bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price of the bidder or any other bidder, or to fix any overhead, profit. or cost element of the bid price, or of that of any other bidder. All statements contained in the bid are true. The bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, to any, corporation, partnership, company, association, organization, bid depository, or to any member or agent thereof, to effectuate a collusive or sham bid, and has not paid, and will not pay, any person or entity for such purpose.

Any person executing this declaration on behalf of d bidder that is a corporation, partnership, joint venture, limited liability company, limited liability partnership, or any other entity, hereby represents that he or she has full power to execute, and does execute, this declaration on behalf of the bidder.

I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct and that this declaration is executed on
12/23/2020 . at Vista CA
Date) (City) (State)
Signature
Dmitriy Zagorodniy
Printed Name
CEO
Title
38 01/11/2022 C6 22 of 56

39 BID SECURITY FORM
Note:This form is to be used when the Bidder chooses to submit cash or a check instead of a bid bond as bid security.Cash or a cashier’s or certified check in the amount of not less than ten percent 10%)of the total Base Bid must accompany the bid.

KNOW ALL PERSONS BY THESE PRESENTS that:

WHEREAS the City of Vista Agency”)has issued an invitation for bids for the work described as follows:

Moonlight Restrooms Renovation

WHEREAS
Name,address,and telephone number of Bidder)
the undersigned bidder Bidder”),has submitted the accompanying bid to Agency for the work.

WHEREAS,bidders are required under the provisions of the Vista Municipal Code to furnish a form of bidder’s security with their bid.

NOW,THEREFORE,the undersigned Bidder,is held and firmly bound unto Agency in the penal sum not less than ten percent 10%)of the total base bid amount,in lawful money of the United States of America in the form of Cash,a Certified Check, a Cashier’s Check Strike out the inapplicable words)for the payment of which sum we bind ourselves,our heirs,executors, administrators,successors,and assigns,jointly and severally,firmly by these presents.

THE CONDITION OF THIS OBLIGATION IS SUCH THAT,if the Bidder shall not withdraw said bid within the period specified in the bidding specification,or,if no period be specified,for ninety 90)calendar days after the bid opening;or if the Bidder does not attempt to withdraw the bid when the requirements of Public Contract Code 5101 et seq.are not met;or if the Bidder is awarded a contract for the work by Agency and,within the time and in the manner required by the bidding specification or if no period be specified,within ten 10)working days after the Contract is awarded,enters into the written form of contract included with bidding specification,furnishes the required bonds,one to guarantee faithful performance and the other to guarantee payment for labor and materials,and furnishes the required insurance coverages,then this obligation shall become null and void and the cash or check shall be returned to Bidder;otherwise,the proceeds of the cash or check shall become the property of the Agency and the Bidder shall have no further interest therein.

Text and signatures continued on page 2.]
01/11/2022 C6 23 of 56

40 In case suit is brought against the Bidder based on this obligation,Bidder further agrees to pay all court costs incurred by Agency in the suit and reasonable attorneys’fees in an amount fixed by the court.

IN WITNESS WHEREOF,this instrument has been duly executed by Bidder on the date set forth below,the name of each corporate officer being hereto affixed,and these presents duly signed by its undersigned representative(s)pursuant to authority of its governing body.

Dated:

Bidder
By:

Its
By:

Its
Seal)
This form must be dated,all signatures must be notarized,and evidence of the authority of any person signing as attorney in fact must be attached.
01/11/2022 C6 24 of 56

41 01/11/2022 C6 25 of 56

BID BOND
KNOW ALL PERSONS BY THESE PRESENTS that:

Bond No.:

The Community Development Commission of the City of Vista ("Commission") has issued an invitation for bids for the work described as follows:

Moonlight Restrooms Renovation
SD Remodeling,Inc. PO Box 1488 Rancho Santa Fe CA 92067 T: 858-756-5001 Name, address, and telephone number of Bidder)
the undersigned bidder ("Principal"), has submitted the accompanying bid to Commission for the work.

Bidders are required under the provisions of the Contract to furnish a form of bidder's security with their bid.

NOW, THEREFORE, we, the undersigned Principal, and
The Ohio Casualty Insurance Company 175 Berkeley Street Boston MA 02116 T: 617- 357-9500 Name, address, and telephone number of Surety)
Surety") a duly admitted surety insurer under the laws of the State of California, as Surety, are held and firmly bound unto Commission in the penal sum not less than ten percent (10%) of the total base bid amount, in lawful money of the United States of America, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors, and assigns, jointly and severally, firmly by these presents.

THE CONDITION OF THIS OBLIGATION IS SUCH THAT, if the hereby bounded Principal shall not withdraw said bid within the period specified in the bidding specification, or, if no period be specified, for ninety (90) calendar days after the bid opening; or if the Principal does not attempt to withdraw the bid when the requirements of Public Contract Code §5101 etseq. are not met; or if the Principal is awarded a contract for the work by Commission and, within the time and in the manner required by the bidding specification , or if no period be specified, within ten (10) working days after the Contract is awarded, enters into the written form of contract included with bidding specification, furnishes the required bonds, one to guarantee faithful performance and the other to guarantee payment for labor and materials, and furnishes the required insurance coverages, then this obligation shall become null and void; otherwise, it shall be and remain in full force and effect.

In case suit is brought upon this bond, Surety further agrees to pay all court costs incurred by Commission in the suit and reasonable attorneys' fees in an amount fixed by the court.

Surety, for value received, hereby stipulates and agrees that no change, extension of time for award of a contract after opening of bids, alteration, addition, modification, or supplement to the terms of the bidding documents, the work to be performed thereunder, or the Contract Documents shall in any way affect Surety's obligations under this Bond, and Surety does hereby waive notice of any such change, extension of time, alteration, addition, modification or supplement to the terms of said Bidding Documents, the Work to be performed thereunder, or the Contract Documents. Surety hereby waives the provisions of California Civil Code §§ 2819, 2845, and 2849. Commission is an intended beneficiary of this bond and has all rights of a party thereto.

Text and signatures continued on page 2.]
42 01/11/2022 C6 26 of 56

IN WITNESS WHEREOF, this instrument has been duly executed by Principal and Surety, on the date set forth below, the name of each corporate party being hereto affixed, and these presents duly signed by its undersigned representative(s) pursuant to authority of its governing body.

Dated: Dezember 17, 2020
Principal"
SD Remodeling, Inc.

By: -am
Signature
Name and Title
Signature
Name
Seal)
Surety"
The Ohio Casualty Insurance Company
Name and Title
Signature
Name
Seal)
This bond must be dated, all signatures must be notarized, and evidence of the authority of any person signing as attorney -in -fact must be attached.
43 01/11/2022 C6 27 of 56

CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT
JA notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.

STATE OF CALIFORNIA
County of Orange
r
On " =fir 0 before me, Robyn R. Kargari Notary Public,
Date Insert Name of Notary exactly as it appears on the official seal personally appeared
LoF„ ROBYN R. KARGARI
COMM, # 2296844 X
Co -
V ,
NOTARY PUBLI0.OALIFORNIA X

ORANGE COUNTY N
MY COMM, EXP. JULY 13, 2073
Irene Luong
Name(s) of Signer(s)
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.

I certify under PENALTY OF PERJURY under the laws of
the State of California that the foregoing paragraph is true and correct.

Witness my h and o ial seal.

Signature ez
Place Notary Seal Above gnaiur d ry Publ o Robyn R. Kargari

OPTIONAL
Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document.

Description of Attached Document
Title or Type of Document:

Document Date:

Signer(s) Other Than Named Above:

Capacity(ies) Claimed by Signer(s)
Signer's Name:

Individual
Corporate Officer Title(s):

Partner Limited General
Attorney in Fact
Trustee
Guardian or Conservator
Other:

Signer is Representing:

Number of Pages.

Signer's Name:

Individual
Corporate Officer —Title(s)
Partner Limited General
Attorney in Fact
Trustee
Guardian or Conservator
Other:

Signer is Representing:
01/11/2022 C6 28 of 56

This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated.

Liberty Liberty Mutual Insurance Company
mutu4.l. The Ohio Casualty Insurance Company Certificate No: 8202900-986938 SURETY
west American Insurance Company

POWER OF ATTORNEY
KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the "Companies"), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, Emilie George; Irene Luon ; James W Moilanen; Yung T Mullick; P Austin Neff all of the city of Oakland state of CA each individually if there be more than one named, its true and lawful attorney -in -fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons
IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 13ih day of January , 2020 .

Liberty Mutual Insurance Company
JAaRpoU? JQ4=ova $U P nNaUR1 The Ohio Casually Insurance Company a ` r o m - `_ o v a 9'F 0 WestAmerican Insurance Company e o m
1912 p 1919 n Lu
1991 n
eh * let 3Hu # b atiyl * By. l _
David M. Carey, Assistant Secretary
State of PENNSYLVANIA ss
County of MONTGOMERY
O On this 13th day of January , 2020 before me personally appeared David M. Care who acknowledged himself to be the Assistant Secretor of Liberty Mutual InsuranceYrYPYPPY 9 Secretary riY o to Company, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes G thereln contained by signing on behalf of the corporations by himself as a duly authorized officer. a IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at King of Prussia, Pennsylvania, on the day and year first above written.

O
Qypa

COMMONWEALTH OF PENNSYLVANIA
0] O g NoteiSeel N
OF Teresa Parterre, Notary Public. Upper
Marion Twp., Montgomery County By: My
Commission Expires March 28, 2021 Teresa Pastella, Notary Public N ARY Mampyr,
PeNt9yrvmdu Association or Notaries C
This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual Insurance E• Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows: O

ARTICLE
IV— OFFICERS: Section 12 Power of Attorney Any
officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the President may prescribe, shall appoint such attorneys -in -fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all a undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact, subject to the limitations set forth in their respective powers of attorney, shall have full O power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such instruments shall Z 0 be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attomey-in-fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by The officer or officers granting such power or authority. ARTICLE XIII — Execution of Contracts: Section 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shall appoint such attomeys-in-fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company When so executed such instruments shall be as binding as if signed by the presidenl and attested by the secretary. Certificate of Designation — The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such attorneys -in - fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations.

Authorization —
By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed. I,
Renee C Llewellyn, the undersigned, Assistant Secretary, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. IN
TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 17th day of December , 2020 P4 VNSURR SY IN$& a 1N3!/+pq j
i?onQo oLn[nzS:orevwa r n a :Nc'o m 1912
1919 n 1991 n t
vd% °
y: m a a ? By: 8,
17*usa ° yn,MP+sa Y,1p,,
x da Renee C. Llewellyn, Assistant Secretary 1-
LMS-
12873 LMIC OCIC WAIC Multi Co 12119 C
c
Oco
W
t
srn
01/11/2022 C6 29 of 56

No. 5133-4

STATE OF CALIFORNIA

DEPARTMENT OF INSURANCE

SAN FRANCISCO
Amended
Certificate of Authority
THIS IS TO CERTIFY, That, pursuant to the Insurance Code of the State of California, The Ohio Casualty Insurance Company
ofNew Hampshire, organized under the laws ofNew Hampshire, subject to its Articles oflncorporation or otherfundamental organizational documents, is hereby authorized to transact within this State, subject to all provisions of this Certiflcate, the following classes of insurance:

Fire, Marine, Surety, Plate Glass, Liability, Workers' Compensation, Common Carrier Liability, Boiler and Machinery, Burglary, Credit, Sprinkler, Automobile and Miscellaneous
as such classes are now or may hereafter be defined in the Insurance Laws of the State of California.

THIS CERTIFICATE is expressly conditioned upon the holder hereofnow and hereafter being in full compliance with all, and not in violation ofany, ofthe applicable Taws and lawful requirements made under authority ofthe laws ofthe State of California as long as such laws or requirements are in effect and applicable, and as such laws and requirements now are, or may hereafter be changed or amended.

IN WITNESS WHEREOF, effective as of the 19" day of March, 2013, I have hereunto set my hand and caused my official seal to be affixed this 19" day of March, 2013.

Dave Jones
Insurance Commissioner
By Valerie J. Sarfaty
for Nettie Hoge
Chief Deputy
NOTICE:

Qualification with the Secretary of State must be accomplished as required by the California Corporations Code promptly after issuance ofthis Certificate of Authority. Failure to do so will be a violation oflnsurance Code section 701 and will be grounds for revoking this Certificate of Authority pursuant to the covenants made in the application therefor and the conditions contained herein.
01/11/2022 C6 30 of 56

Premium is subject to change based on the final contract amount Bond No. 024249000
Premium: $ 3,343.00
Effective Date: January 20, 2021

PERFORMANCE BOND
Executed in Duplicate
LD; GP; DWG
APN
KNOW ALL PERSONS BY THESE PRESENTS that: *SD Remodeling, Inc.

The City of Vista ("City") has awarded a contract (the "Contract") to THEPRINCIPAL* ("Principal") for the work described as follows:

Moonlight Restrooms Renovation
which Contract, and all Contract Documents set forth therein, are incorporated herein and made a part thereof by this reference.

Principal is required underthe terms of the Contract to furnish a bond guaranteeing the prompt, full, and faithful performance of the Contract concurrently with delivery of the signed Contract to City.

NOW, THEREFORE, we, the undersigned Principal, and
The Ohio Casualty Insurance Company 175 Berkelev Street. Boston, MA 02116 T: 617-357-9500 Name, address, and telephone number of Surety)
One Hundred Thirty Three Thousand Seven Hundred and 00/100 ($ 133 700.00) Surety") a duly admitted surety insurer under the laws of the State of California, as Surety, are held and firmly bound unto veCityinthepenalsumofamountDollars ($xxx), tt is amount being not less than one hundred percent (100%) the total contract price, in lawful money of the United States of America, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors, and assigns, jointly and severally, firmly by these presents.

THE CONDITION OF THIS OBLIGATION IS SUCH THAT, if the hereby bounded Principal, his, her or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform all the undertakings, terms, covenants, conditions and agreements in the Contract and any alteration thereof made as therein provided, on Principal's part to be kept and performed, all within the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and hold harmless City and its officers, agents, and others as therein provided, from any and all losses, liability and damages, claims, judgments, stop payment notices, costs, and fees of every description, whether imposed by law or equity, which may be incurred by City by reason of the failure or default on the part of Principal in the performance of any or all of the terms or the obligations of the Contract Documents, as they may be amended and supplemented including, but not limited to, Principal's liability for City's damages (including direct and consequential damages incurred by City for: rental expenses; losses of use, income, profit, business, and reputation; increased financing costs; and loss of management or employee productivity or of the services of such persons) caused by Principal's delays, as well as Principal's liability for other delay damages or liquidated damages, and any warranties or guarantees required thereunder; then this obligation shall become null and void; otherwise, it shall be and remain in full force and effect.

When City declares that Principal is in default under the Contract, Surety shall promptly, take one of the following actions:
a) Remedy the default;
b) Undertake through its agents or independent contractors reasonably acceptable to City, to complete the Project according to the Contract Documents' terms and conditions then in effect including without limitation, all obligations with respect to warranties, guarantees, and the payment of liquidated damages; or, if required by City; 11 01/11/2022 C6 31 of 56

c) Obtain a bid or bids for completing the Contract in accordance with its terms and conditions using a procurement methodology approved by City, select a contractor or contractors — acceptable to City — to complete all of the Work, and arrange for a contract between the contractor(s) and City, to be secured with performance and payment bonds executed by an admitted surety insurer equivalent to the bonds issued on the Construction Contract, and Surety shall make available, as the Work progresses, sufficient funds to pay the cost of completion less the balance of the Contract Sum, and to pay and perform all obligations of Principal under the Contract and Contract Documents, including other costs and damages for which Surety is liable under this Bond and all obligations with respect to warranties, guarantees, and the payment of liquidated damages as a result of Contractor's default;
d) Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances:
i) After investigation, determine the amount for which it may be liable to City and, as soon as practicable after the amount is determined, make payment to City; or
ii) Deny liability in whole or in part and notify City, citing the reasons for denial.

If Surety does not proceed as provided above with reasonable promptness, Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from City to Surety demanding that Surety perform its obligations under this Bond, and City shall be entitled to enforce any remedy available to City. If Surety admits liability and tenders payment, and City refuses the payment, or Surety has denied liability, in whole or in part, without further notice City shall be entitled to enforce any remedy available to City.

In case suit is brought upon this bond, Surety further agrees to pay all court costs and reasonable attorneys' fees in an amount fixed by the court. Principal and Surety agree that this Performance Bond shall not be considered a part of the Contract but rather is a separate obligation of Principal and its Surety, and that any attorneys' fee provision contained in this Performance Bond shall not apply to the Contract. In the event there is any litigation between the parties arising from the breach of the Contract, each party will bear its own attorneys' fees in the litigation.

FURTHER, Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration, addition or modification to the terms of the Contract, or of the work to be performed thereunder, or the specifications for the same, shall in any way affect its obligations under this bond, and it does hereby waive notice of any such change, extension of time, alteration, addition, or modification to the terms of the Contract or to the work or to the specifications thereunder. Surety hereby waives the provisions of California Civil Code §§ 2819, 2845, and 2849. City is an intended beneficiary of this bond and has all rights of a party thereto.

Text and signatures continued on page 3.]
49 01/11/2022 C6 32 of 56

IN WITNESS WHEREOF, two (2) identical counterparts of this instrument, each of which shall for all purposes be deemed an original hereof, have been duly executed by Principal and Surety, on the date set forth below, the name of each corporate party being hereto affixed and these presents duly signed by its undersigned representative(s) pursuant to authority of its governing body.

Dated: January 20, 2021
Principal"
SD Remodeling, Inc.

THEPRINCIPAL
I J
By:(/Ir[ rU A
v'
Signature
1)A(Z I
NameandTitle Signature
Name
Seal)
Surety"
R--- • =-
IMMUMUir-MIRERM Name
and Title By:

Signature
Name
Seal)
This
bond must be dated, all signatures must be notarized, and evidence of the authority of any person signing as attorney -in -fact must be attached. 50
01/11/2022 C6 33 of 56

CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.

STATE OF CALIFORNIA
County of Orange
On f 97 , before me, Robyn R. Kar ari Notary Public,
to Insert Name of Notary exactly as it appears on the official seal personally appeared Irene Luang
Names) of Signer{ay
Lar r,
a
ROB R. KARGARI
s COMM, # 2296t344 X
H NOTARY PUSLIC•CALIFORNIA N
tY r ORANGE COUNT IN
MY COMM. EXP. JULY 13, 2023
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that helshelthey executed the same in hislherltheir authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
certify under PENALTY OF PERJURY under the laws of
the State of California that the foregoing paragraph is true and correct.

Witness my hart vial seal.

Signature
Place Notary Seal Above S!NoAlgwafl4emry Public Robyn RKaargari

OPTIONAL
Though the information below is not required by law it may prove valuable to persons relying on the documentandcouldpreventfraudulentremovalanJreattachmentoftheformtoanotherdocument.

Description of Attached Document
Title or Type of Document:

Document Date:

Signer(s) Other Than Named Above:

Capacity(ies) Claimed by Signer(s)
Signer's Name
Individual
Corporate Officer----Title(s):

Partner Limited General
Attorney in Fact
Trustee
Guardian or Conservator
Other:

Signer is Representing:

Number of Pages:

Signer's Name:

Individual
Corporate Officer—Title(s):

Partner Limited General
Attorney in Fact
Trustee
Guardian or Conservator
Other:

Signer is Representing:
01/11/2022 C6 34 of 56

V a)
v:3
M
W
a
W'rn
02 do
Ca) N
N !
Liberty
Mutual.

SURETY
This Power of Attorney limits the acts of those named herein, and they have no a uthority to bind the Company except in the manner and to the extent herein stated.

Liberty Mutual Insurance Company
The Ohio Casualty Insurance Company
West American Insurance Company

POWER OF ATTORNEY
Certificate No: 8202900-986938
KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the "Companies"), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, Emilie George; Irene Luong; James W. Moilanen; Yung T. Mullick; P. Austin Neff all of the city of Oakland state of CA each individually if there be more than one named, its true and lawful attorney -in -fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons.

Liberty Mutual Insurance Company
trlsr,V rNsG t suRq The Ohio Casualty Insurance Company ti3a°`°O'4ri,o yS oa p4'Z°T io°"P°'r t0 West American Insurance Company a n
1912 0 1919 n LU
1991
d11ys'lACHvgaa SONR A149 a vN°IA F a ?r ' r
rou•
7c5
By• -
David M. Carey, Assistant Secretary
State of PENNSYLVANIA ss
County of MONTGOMERY
On this 13th day of January , 2020 before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of Liberty Mutual Company, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the therein contained by signing on behalf of the corporations by himself as a duly authorized officer.

IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at King of Prussia, Pennsylvania, on the day and year first above written. ap FA$F COMMONWEALTH OF PEHTFBYLVANiA
R
q Notarial Seal
OF Teresa Pastella, Notary Public
Upper Merion Twp., Montgomery County By:

My Commission Expires March 28, 2021 Teresa Pastella, Notary Public ft
MOMW. PEr+gygvenln ASio440M or Nolaries
IThis Power of Attomey is made and executed pursuant to and by aulhority of the follow4ng By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows:
8 ARTICLE IV— OFFICERS: Section 12, Power of Attorney.

L Any the Corporation for that inofficerorotherofficialofauthorizedpurpose writing by the Chairman or the President, and subject to such limitation as the Chairman or the President may prescribe, shall appoint such attorneys -in -fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact, subject to the limitations set forth in their respective powers of attorney, shall have full o0
2 power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such instruments shall Iv 0 be as binding as If signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attomey-in-fact under the provisions of this article may be rmked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority.

ARTICLE All — Execution of Contracts: Section 5. Surety Bonds and Undertakings. 0 Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, r shall appoint such allomeys-in-fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary.

Certificate of Designation — The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such attorneys -in - fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations.

I, Renee C. Llewellyn, the undersigned, Assistant Secretary, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked.

IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 20th day of January , 2021 .

Pv INsl1 11 IN 141bu/R
i pRFORq y S &Pop.? W_ QRS'OR 4
sty rPc nrn Ua R Fa m lu 3° o m
1912 n 1919a a 4 1991 0
rd3S 7 au laaA°"*"hHda rs*"aa By.

Renee C. Llewellyn, Assistant Secretary
LMS-12873 LMIC OCIC WAIC Multi Co 12/1901/11/2022 C6 35 of 56

Bond No. Q24249000 _
Premium: $included in Performance Bond
Effective Date: January 20, 2021
PAYMENT BOND Executed in Duplicate

LABOR AND MATERIALS)
LD; GP; DWG
APN
KNOW ALL PERSONS BY THESE PRESENTS that: *
SD Remodeling, Inc.

The City of Vista ("City") has awarded a contract (the "Contract") to THEPRINCIPAe ("Principal") for the work described as follows:

Moonlight Restrooms Renovation
which Contract, and all Contract Documents set forth therein, are incorporated herein and made a part thereof by this reference.

Principal is required underthe terms of the Contract and the California Civil Code to furnish a bond to secure the prompt, full, and faithful payment of any Claimant, as hereinafter defined, for all labor, materials or services used or reasonably required for use in the performance of the work, concurrently with delivery to City of the signed Contract.

NOW, THEREFORE, we, the undersigned Principal, and
TheOhio-Q!asuglty Insurance Company - -
Name, address, and telephone numberof5urety)
One Hundred Thirty Three Thousand Seven Hundred and 00/100 ($ 133,700.00) Surety') a duly admitted surety insurer under the laws of the State of California, as Surety, are held and firmly bound unto Cityin the penal sum of amount Dollars $xxx ,s above g not less than one hundred percent (100%) of the totalp ( ) 1 a amount being contract price, in lawful money of the United States of America, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors, and assigns, jointly and severally, firmly by these presents.

THE CONDITION OF THIS OBLIGATION IS SUCH THAT, if the hereby bounded Principal, his, her or its heirs, executors, administrators, successors or assigns, or subcontractors shall fail to pay any of the persons named in Division 4, Part 6, Title 3 of the California Civil Code (§ 9000 et seq.), or any amounts due under the Unemployment Insurance Code with respect to work or labor performed under the Contract, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of Principal and subcontractors pursuant to Section 13020 of the Unemployment Insurance Code, with respect to work or labor performed under the Contract ("Claimants"), Surety will pay for the same in an amount not exceeding the penal sum specified in this bond; otherwise, this obligation shall become null and void.

This bond shall inure to the benefit of any of the persons named in Division 4, Part 6, Title 3 of the California Civil Code (§ 9000 et seq.), so as to give a right of action to such persons or their assigns in any suit brought upon the bond.

In case suit is brought upon this bond to enforce or interpret this bond's terms, Surety further agrees to pay all court costs and reasonable attorneys' fees in an amount fixed by the court. Principal and Surety agree that this Performance Bond shall not be considered a part of the Contract but rather is a separate obligation of Principal and its Surety, and that any attorneys' fee provision contained in this Performance Bond shall not apply to the Contract. In the event there is any litigation between the parties arising from the breach of the Contract, each party will bear its own attorneys' fees in the litigation.

shall in any way affect its obligations under this bond, and it does hereby waive notice of any such change, extension of time, alteration, addition, or modification to the terms of the Contract or to the work or to the specifications thereunder. Surety hereby waives the provisions of California Civil Code §§ 2819, 2845, and 2849. City is an intended beneficiary of this bond and has all rights of a party thereto.

IN WITNESS WHEREOF, this instrument has been duly executed by Principal and Surety, on the date set forth below, the name of each corporate party being hereto affixed and these presents duly signed by its undersigned representative(s) pursuant to authority of its governing body.

Dated: January 20,2021
Principal"
SD Remodeling, Inc.

THEPRINCIPAL
By: I
Signature
Name and Title
By:

Signature
Name
Seal)
Surety"
The Ohio Casualty Insurance Company
By:

Name and Title
Signature
Name
Seal)
This bond must be dated, all signatures must be notarized, and evidence of the authority of any person signing as attorney -in fact must be attached.
52 01/11/2022 C6 37 of 56

STATE OF CALIFORNIA
County of Orange
On J AN 2 Q 2021 before me, Robyn R. Kargari Notary Public, Date Insert Name of Notary exactly as it appears on the official seal personally appeared Irene Luong
Names) of Signer(s)
ryF ROBYN R. KARGARI
o- COMM. # 2296844
NOTARY PUBLIC-CALIFORNIA Cn

ORANGE COUNTY N
MY COMM. EXP, JULY 13, 2Q23
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) Ware subscribed to the
within instrument and acknowledged to me that helshelthey executed the same in hisfherltheir authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.

I certify under PENALTY OF PERJURY under the laws of
the State of California that the foregoing paragraph is true and correct.

Witness my ha Icial seal.

Signature
Place Notary Seal Above ' n_ ry Pu is Robyn R. Ka—rgarl

OPTIONAL
Though the information below is not required by law it may prove valuable to persons relying on the documentandcouldpreventfraudulentremovalandreattachmentoftheformtoanotherdocument.

Description of Attached Document
Title or Type of Document:

Document Date:

Signer(s) Other Than Named Above:

Capacity(lies) Claimed by Signer(s)
Signer's Name:

Individual
Corporate Officer ----Title(s):

Partner Limited General
Attorney in Fact
Trustee
Guardian or Conservator
Other:

Signer is Representing:

Number of Pages: _ _
Signer's Name:

Individual
Corporate Officer Title(s):

Partner Limited General
Attorney in Fact
Trustee
Guardian or Conservator
Other:

Signer is Representing:
01/11/2022 C6 38 of 56

V ()
ocu
wCU
W
Ca 'to
a
do
C a)
0 N ++
ONLibertyMutual rc.

SURETY
This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein slaters.

Liberty Mutual Insurance Company
The Ohio Casualty Insurance Company
West American Insurance Company

POWER OF ATTORNEY
Certificate No: 8202900-986938
KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the "Companies"), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, Emilie Geor c; Irene Luon ; James W. Moilanen; Yun T, Mullick; P. Austin Neff all of the city of Oakland state of CA each individually if there be more than one named, its true and lawful attorney -in -fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons.

IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 13r11 day of January , 2020 .
tHs
Liberty Mutual Insurance Company
tNSUp ,sv I sUpq The Ohio Casually Insuranoe Company
co4nwR,tnm 4a}`ow5e, a°soe',
e m West American Insurance Company
1912 s:F1919 a 1991 0
Ne u9 as r°rrarrB'' dad rye
0z7 * h1 * r 3yt * ? By:

David M. Carey, Assistant Secretary
State of PENNSYLVANIA ss
County of MONTGOMERY
On this 13th day of January , 2020 before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance Company, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer.

IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at King of Prussia. Pennsylvania, on g P CST
COMMONWEALTH OF PENHSYLVAkUA
1 y` Ckkr p Notarial Seal
OF Teresa Pastella, Notary Public,
Upper Marion Twp., Montgomery County By:

My
LV
wr M
Commission Expires March 28, 2021
eresa Pastella, Notary Public
Mumpw, PonyFranlu Association of Notaries
This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows:
the day and year first above written.

ARTICLE IV— OFFICERS: Section 12. Power of Attorney.

Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the President may prescribe, shall appoint such attorneys -in -fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact, subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such instruments shall 0 be as binding as if signed by the President and attested to by the Secretary. Any paver or authority granted to any representative or attomey-in-fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or aulhority.

ARTICLE All — Execution of Contracts: Section 5. Surety Bonds and Undertakings.

Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shall appoint such altomeys4n-fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the sembry.

Certificate of Designation — The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M Carey, Assistant Secretary to appoint such attorneys -in - fad as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations.

I, Renee C. Llewellyn, the undersigned, Assistant Secretary, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify [hat the original power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked.

IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 20th day of January , 2021 . 41NSUR 01 IN 1NSO&
Po r ayn a`flgpwy"4.
uuPRr ogaT ym
1912 a 1919 n 1991
w p d Q
Acnu9 aaa By
RenBB C. Llewellyn, Assistant Secretary7
C
9 c0
V)
W
LMS-12873 LMIC OCIC WAIC Multi Co 12/1901/11/2022 C6 39 of 56

01/11/2022 C6 40 of 56EXHIBIT 4

01/11/2022 C6 41 of 56

EXHIBIT 5
Original Contract Amount $ 133,700.00
Change Orders Description Cost Notes
Change Order 2 Replace Drywall , angle stops $ 8,156.95 Approved by City Manager Change Order 3
Replace rotted subflooring 12‐14" from shared
plumbing wall, remove epoxy floor, replace
damaged subfloor
$ 9,562.25 Approved by City Manager
Change Order 4 Plumbing repairs $ 9,764.97 Approved by City Manager Change Order 5
City changed sink specs from Bradley Omnideck
to Badeloft. Original Bradley sinks came with
faucets and soap dispensers, Badelofts do not.

Change Order to reduce cost.
$ (3,256.98) Approved by City Manager
Change Orders Total $ 24,227.19
Contract Total (updated) $ 157,927.19
01/11/2022 C6 42 of 56EXHIBIT 5

01/11/2022 C6 43 of 56

01/11/2022 C6 44 of 56

GO Builders Inc
CONTRACT TITLE: Moonligh Restrooms Renovation Project DATE: 11/3/2021 Change Order No. 02 CP21-0935-23
SCOPE OF WORK: Demolition, Seal Caulking, Install New Drywall, Water Protection, and Plumbing to Replace Damaged Drywall and Replace Angle Stops for Every Sink 1. Replace damaged drywall in Women's Restroom (44' long and 4' high) 2. Replace damaged drywall in Men's Restroom (27' long and 4' high) 3. Replace 3 angle stops and 6 flex lines in Women's Restroom 4. Replace 3 angle stops and 6 flex lines in Men's Restroom
Payment -Extra, Additional, Deleted Work, Allowances, or Contractor Contingencies

PAYMENT EXTRA/ADDITIONAL/ ALLOWANCES/

DELETED WORK CONTINGENCIES

1. General Contractor Material and Egui11ment
a. Attach itemized quantity and unit cost plus sales tax. b.Include information where derived, i.e., "Means Building Construction Cost Data" $1,285.00 $0.00 or other source mutually agreed to by all parties.

2. General Contractor Labor
Attach itemized hours and rates per certified payrolls, prevailing wage chart and PSA agreements. Rates shall only include a maximum of 15% for payroll $ 5,808.00 $0.00 burden plus actual costs for Workers' Compensation Insurance. Payment for extra supervision will be paid when extra Work is done in a time period other than normal Working hours.
3 , Subtotal: Item #1 plus Item #2 $ 7,093.00 $0.00

4. Ger:ieral Contractor's Overhead, Profit, Su11ervlsion, Bond Fees (A maximum aggregate total of 16% of Item #3.)
This item is not allowed on Extended Overl'iead Allowances or $ 1,063.95 Conlractor Contingencies.

5.Total General Contractor: Item #3 plus Item #4 $ 8,156.95 $0.00

6.Subcontractor Matecial and EgLJl[!men!
a. Attach itemized quantity and unit cost plus sales tax. b.Include information where derived, i.e., "Means Building $-$0.00 Construction Cost Data" or other source mutually agreed to by all parties.

7.Subcontractor Labor
Attach itemized hours and rates per certified payrolls, prevailing wage chart, and PSA agreements. Rates shall only include a maximum of 15% for payroll burden plus $ $0.00 actual costs for Workers' Compensation Insurance. Payment for extra supervision - will be paid when extra Work is done in a time period other than normal Working hours.

8. Subtotal: Item #6 plus Item #7 $-$-

9.General Contractors' Overhead, Su12ervlslon, Bond Fees and Profit for Subcontractor Work
(A maximum aggregate total of 11 % of Item #8.) $--This item is not allowed on Extended Overhead, Allowances, or Contra!,lor Conlingencjes.

10.Subcontractor's Overhead and Profit
Maximum aggregate total of 15% of Item #8. Not to be included for Work provided by Contractor. No sub-tier markups allowed, Attach signed Subcontractor documentation on Subcontractor letterhead. $ $-
Tbis item is not allowed on Extended Overhead, Allowances, or Conlractor Contingeocies.

11.Subtotal: Item #9 plus Item #10.$-$ -
TOT AL: Item #5 plus Item #8 plus Item #11, $ 8,156.95 $ - 01/11/2022 C6 45 of 56

01/11/2022 C6 46 of 56

01/11/2022 C6 47 of 56

01/11/2022 C6 48 of 56

01/11/2022 C6 49 of 56

01/11/2022 C6 50 of 56

01/11/2022 C6 51 of 56

01/11/2022 C6 52 of 56

01/11/2022 C6 53 of 56

01/11/2022 C6 54 of 56

01/11/2022 C6 55 of 56

CONTRACT TITLE: Moonligh Restrooms Renovation Project DATE:12/20/2021

PAYMENT ALLOWANCES/

CONTINGENCIES

3. Subtotal: Item #1 plus Item #2 $0.00

5. Total General Contractor: Item #3 plus Item #4 $0.00

8. Subtotal: Item #6 plus Item #7 $-

This item is not allowed on Extended Overhead, Allowances, or Contractor Contingencies.
$-

11. Subtotal: Item #9 plus Item #10. $-
TOTAL: Item #5 plus Item #8 plus Item #11. $-

CALENDARD

Attachment 1A, Hourly Labor Rate Worksheet must accompany all change orders, allowances or contingencies.

EXTRA/ADDITIONAL/

DELETED WORK
$185.00
$2,550.00
$2,735.00
$410.25
ESTIMATED TIME: (Zero, unless indicated; “TBD” not allowed) $3,145.25
$-
$-
$-
$-
$-
ATTACHMENT 1
GQ Builders Inc
Existing drywall on the ceiling is damaged due to moisture and needs to be replaced. Remove damaged drywall approximately 40 sq/ft install new drywall, drywall finishing, apply texture, prime and paint. $-
$3,145.25
CP21-0935-23
Payment – Extra, Additional, Deleted Work, Allowances, or Contractor Contingencies Change Order No. 06 Women's Restroom
01/11/2022 C6 56 of 56

Vista City CouncilJanuary 11, 2022

Vista City Council
January 11, 2022