Fax: ( ) -
( ) -Phone:
Mail Drop 999 P.O. Box 748552
Atlanta, GA 30384-8552
Proposal ID: 235129
Stephanie Langford $129,309.59
We PROPOSE to perform the work complete in accordance with the specifications and as described above for the SUM of:
Signature:
Conditions of Proposal:
Stephanie Langford
Email: [email protected]
1. This Proposal may be withdrawn, if not accepted, within 30 days of its issuance. Shaw Industries Group, Inc. will consider reasonable requests to engage in negotiations for revisions to this Proposal, including signing a subcontract that includes the terms of this Proposal. A proposal not accepted within 30 days will be subject to price escalation of materials, labor, freight and fuel costs.
2. This proposal is subject to credit review and approval. Payment terms are net 30 days. A convenience fee of 3% will be added if paying via credit card. Past due invoices are subject to service charges of 1.5% per month (18% per annum). In the case of any default, Customer shall pay Shaw Integrated and Turf Solutions, Inc.'s reasonable attorney fees and costs, including those on any appeal, even if no suit or action is filed.
3. All work shall be performed in a workmanlike manner according to industry standards. Areas to receive flooring shall be free and clear of debris. Any changes to the work shall be performed only after execution of a written change order.
4. Prior to commencement of Shaw Industries Group, Inc.'s work: (a) Customer shall test all concrete sub floors receiving flooring for vapor emission levels and alkalinity per manufacturers' recommendations utilizing ASTM F2170 and provide written results to Shaw Industries Group, Inc., including a list of any sealers applied to the concrete sub floor; (b) If Customer does not provide such reports at least 10 days prior to commencement of Shaw Industries Group, Inc.'s work, then Customer shall provide Shaw Industries Group, Inc. with access to all concrete sub floors for appropriate testing and Customer shall be responsible for the costs of such testing; and (c) Any concrete sub floors not meeting manufacturers' requirements for installation will require correction or the execution of a separate waiver agreement.
5. All work is contingent upon strikes, accidents or delays beyond Shaw Industries Group, Inc.'s control. Customer shall carry insurance for all hazards, including fire. Shaw Industries Group, Inc.'s workers are fully covered by Worker's Compensation and Liability Insurance.
6. Customer represents and warrants that: (a) the project site contains no hazardous or other dangerous substances, either exposed or concealed; or (b) Customer has given written notice to Shaw Industries Group, Inc. of all such substances and their location(s). To the fullest extent permitted by law, Customer shall indemnify, defend and hold Shaw Industries Group, Inc. harmless from any damage, claim, loss, expense and attorney fees related to Shaw Industries Group, Inc.'s liability, if any, including any federal or state statute related to hazardous or other dangerous substances.
7. Shaw Industries Group, Inc. is fully licensed, bonded, and insured. This proposal does not include participation in any OCIP/CCIP or related programs. Requests for Shaw Industries Group, Inc. to participate in such programs may result in additional costs.
8. Notwithstanding anything herein to the contrary, all prices are subject to immediate increase without limitation in the event of material change to applicable duties, taxes, tariffs, similar charges, or other government action.
ACCEPTANCE OF PROPOSAL: The above prices, specifications, and conditions are satisfactory and are hereby ACCEPTED.
City of Carson Signed:Customer: Date:
You are authorized to do the work as specified.
PA# 2020002144
Purchasing Agreement 2020002144
As a result of Request for Proposal #001225 -May2019 (University of California Systemwide Flooring), t he Agreement to furnish certain goods and services described herein and in the documents referenced herein (“ Goods and/or Services”) is made by and between The Regents of the University of California, a California public corporation (“UC”) on behalf of the University of California, and Shaw Industries, Inc. (“Supplier”). This Agreement is binding only if it is negotiated and executed by an authorized representative with the proper delegation of authority.
1. Statement of Work
Supplier agrees to perform the Services listed in the statement of work attached as Attachment A (“Statement of Work”) and any other documents referenced in the Incorporated Documents section herein , at the prices set forth in the Statement of Work and any other documents referenced in the Incorporated Documents section herein. Unless otherwise provided in the Agreement, UC will not be obligated to purchase a minimum amount of Goods and/or Services from Supplier.
2. Term of Agreement/Termination
A) The initial term of the Agreement will be from April 15 th, 2020 through April 14 th, 2025 (Initial Term) and is subject to earlier termination as provided below. UC may renew the Agreement for Five (5) successive One (1)-year periods (each, a Renewal Term), by providing Supplier with at least Thirty (30) calendar days’ written notice before the end of the Initial Term or any Renewal Term.
B) UC may terminate the Agreement for convenience by giving Supplier at least 30 calendar days' written notice.
C) UC or Supplier may terminate the Agreement for cause by giving the other party at least 30 days' notice to cure a breach of the Agreement (Cure Period). If the breaching party fails to cure the breach within the Cure Period, the non-breaching party may immediately terminate the Agreement.
3. Purchase Order; Advance Payments
Unless otherwise provided in the Agreement, Supplier may not begin providing Goods and/or Services until UC approves a Purchase Order for the Goods and/or Services.
4. Pricing, Invoicing Method, and Settlement Method and Terms
A. Pricing. Refer to Attachment B – UC Price Schedule for Pricing.
i. Price Increases – After the first twelve (12) months of the term, or longer term as negotiated between UC and the Supplier, of any resulting contract, the Supplier will have an opportunity to request price increases. Requests for price increases may only be made once a year, in writing, 60 days in advance of the contract anniversary date. Notwithstanding anything herein to the contrary, in the event of material change to applicable duties, taxes, tariffs, similar charges, or other government action University and Supplier shall negotiate in good faith and promptly implement a proportional price increase for impacted products.
a. Product Price Increases – Product price increases will be not exceed the lesser of 3% or the annual increase in the Product Price Index (PPI) for the corresponding commodity:
(1) Vinyl Flooring: Plastics Material and Resins Manufacturing (PCU325211325211) (2) All Carpet Products: Carpet and Rug Mills: Carpets & Rugs (PCU3141103141100) (3) Rubber and Linoleum: Plastics and Rubber Products Manufacturing (PCU326326) DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
PA# 2020002144
(4) Wood Products: Other Millwork, Including Flooring (PCU321918321918)
b. Labor Price Increases – Labor price increases will only be allowed under an increase in the Department of Industrial Relations (DIR) Prevailing Wage Schedule, and will be capped at the corresponding percentage of any DIR increase.
c. Freight – Where applicable, Supplier agrees to maintain freight pricing, in either set rate or as a percentage of spend, consistent with any increase or decrease in the PPI for General Freight Trucking, Long-Distance Truckload (PCU484121484121)
B. Invoicing Method
Each UC Location will specify the Invoicing Method and Payment Options that will apply, taking into account the operational capabilities of Supplier and the UC Location. See UC’s Procure to Pay Standards http://www.ucop.edu/procurement-services/_files/Matrix%20for%20website.pdf for the options that will be considered. In the case of systemwide agreements, each UC Loca tion will specify these terms in a Statement of Work or Purchase Order, as the case may be.
C. Invoicing
Notwithstanding the provisions of Article 3 of the Terms and Conditions of Purchase, UC will pay freight and shipping/handling as follows: FOB Destination – Prepay & Add.
All invoices must clearly indicate the following information:
Charges associated with California AB2398
California sales tax as a separate line item;
Shipping costs as a separate line item;
UC Purchase Order or Release Number;
Description, quantity, catalog number and manufacturer number of the item (s) ordered; Net cost of each item;
Description, quantity, and pay rate of any services provided Any pay/earned/dynamic discount;
Reference to original order number for all credit memos issued;
Supplier will submit invoices following the designated invoice method directly to UC Accounts Payable Departments at each UC Location, unless UC notifies the Supplier otherwise by amendment to the Agreement.
D. Settlement Method and Terms
Notwithstanding the provisions of Article 3 of the Terms and Conditions of Purchase, the Settlement Method and Terms will be as follows: ACH Net60
E. Additional Discounts
Supplier Agrees to provide additional volume based discounts at the following Tier structure:
Tier 1 Discount: 5% on product purchases of $75,001 – 150,000.
Tier 2 Discount: An additional 5% on product purchases of $150,001+
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
PA# 2020002144
5. Notices
As provided in the UC Terms and Conditions of Purchase, notices may be given by email, which will be considered legal notice only if such communications include the following text in the Subject field: FORMAL LEGAL NOTICE – [insert, as the case may be, Supplier name or University of California]. If a physical format notice is required, it must be sent by overnight delivery or by certified mail with return receipt requested, at the addresses specified below.
To UC, regarding contract issues:
Name Reynaldo Cano-Boza
Phone 510.987.9893
Email [email protected]
Address 7835 Trade Street, Suite 100
San Diego, CA 92121
To Supplier:
Name Don Chupik, VP of Government & Education
Phone 714.944.7500
Email [email protected]
Address 616 E Walnut Ave
Dalton, GA 30722-2128
6. Intellectual Property, Copyright and Patents
/_X / The Goods and/or Services do not involve Work Made for Hire
7. Patient Protection and Affordable Care Act (PPACA)
/_X / The Services do not involve temporary or supplementary staffing, and they are not subject to the PPACA warranties in the T&Cs.
8. Prevailing Wages
Work performed under this agreement is a public work subject to California Labor Code section 1771. Supplier, or sub - Supplier, must be registered with the DIR pursuant to Labor Code section 1725.5. Supplier is required to post the applicable prevailing wage rate determination and any job site notices as prescribed by the DIR. The work is subject to co mpliance monitoring and enforcement by the DIR and is subject to project reporting through the DIR.
9. Fair Wage/Fair Work
/_X_/ Supplier is not required to pay the UC Fair Wage (defined as $13 per hour as of 10/1/15, $14 per hour as of 10/1/16, and $15 per hour as of 10/1/17) when providing the Services.
10. Restriction Relating to Consulting Services or Similar Contracts – Follow-on Contracts
Please note a Supplier that is awarded a consulting services or similar contract cannot later submit a bid or be considered for any work “required, suggested, or otherwise deemed appropriate” as the end product of the Services (see Public Contract Code Section 10515).
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
PA# 2020002144
11. Insurance
Deliver the PDF version of the Certificate of Insurance to UC’s Buyer, by email with the following text in the Subject field:
CERTIFICATE OF INSURANCE – Shaw Industries, Inc.
12. Cooperative Purchasing
Supplier agrees to extend pricing and Goods and/or Services to the California State University institutions (CSU) and the California Community Colleges (CCC) and public agencies nationwide (public and private schools, colleges and universities, cities, cou nties, non -profits, and all governmental entities) registered with OMNIA Partners under the terms of the Agreement. All contractual administration issues (e.g. terms and conditions, extensions, and renewals) will remain UC’s responsibility. Operational i ssues, fiduciary responsibility, payment issues, performance issues and liabilities, and disputes involving individual CSU or CCC campuses will be addressed, administered, and resolved by each CSU or CCC campus.
13. Records about Individuals
Records created pursuant to the Agreement that contain personal information about individuals (including statements made by or about individuals) may become subject to the California Information Practices Act of 1977, which includes a right of access by th e subject individual. While ownership of confidential or personal information about individuals is subject to negotiated agreement between UC and Supplier, records will normally become UC’s property, and subject to state law and UC policies governing privacy and access to files. When collecting the information, Supplier must inform the individual that the record is being made, and the purpose of the record. Use of recording devices in discussions with employees is permitted only as specified in the Statement of Work.
14. Incorporated Documents
This Agreement and its Incorporated Documents contain the entire agreement between the Parties, in order of the below precedent, concerning its subject matter and shall supersede all prior or other agreements, oral and written declarations of intent and other legal arrangements (whether binding or non-binding) made by the Parties in respect thereof.
a. Purchase Agreement 2020002144
b. UC Terms & Conditions of Purchase
c. Attachment A – Statement of Work
d. UC Request for Proposal (#001225-MAY2019) University of California Systemwide Flooring (RFP) e. Attachment B – University of California Price Schedule f. Attachment C – Reporting Requirements
g. Appendix – Ecommerce
15. Entire Agreement
The Agreement and its Incorporated Documents contain the entire Agreement between the parties and supersede all prior written or oral agreements with respect to the subject matter herein.
This Agreement can only be signed by an authorized representative with the proper delegation of authority.
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
PA# 2020002144
THE REGENTS OF THE Shaw Industries, Inc.
UNIVERSITY OF CALIFORNIA
________________________________ ___________________________________ (Signature) (Signature)
________________________________ ___________________________________ (Printed Name, Title) (Printed Name, Title)
________________________________ ____________________________________ (Date) (Date)
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F Treasurer
4/22/2020
Jim Kirkpatrick
Executive DirectorJustin Sullivan
4/23/2020
Revised 5/9/19
Terms and Conditions of Purchase
ARTICLE 1 – GENERAL
The equipment, materials, or supplies (“Goods”) and/or services (“Services”) furnished by Supplier (together, the “ Goods and Services”) and covered by the UC Purchase Order (“PO”) and/or other agreement (which, when combined with these Terms and Conditions and any other documents incorporated by reference, will constitute the “Agreement”) are governed by the terms and conditions set forth herein.
As used herein, the term "Supplier" includes Supplier and its sub -suppliers at any tier. As used herein, “UC” refers to The Regents of the University of California, a corporation described in California Constitution Art. IX, Sec. 9, on behalf of the UC Location s identified in the Agreement and/or the PO. UC and Supplier individually will be referred to as “Party” and collectively as “Parties.” Any defined terms not defined in these Terms and Conditions of Purchase will have the meaning ascribed to such term in any of the other documents incorporated in and constituting the Agreement . No other terms or conditions will be binding upon the Parties unless accepted by them in writing.
Written acceptance or shipment of all or any portion of the Goods, or the performance of all or any portion of the Services, covered by the Agreement, will constitute Supplier’s unqualified acceptance of all of the Agreement’s terms and conditions. The terms of an y proposal referred to in the Agreement are inclu ded and made a part of the Agreement only to the extent the proposal specifies the Goods and/or Services ordered, the price therefor, and the delivery thereof, and then only to the extent that such terms are consistent wi th the terms and conditions of the Agreement.
ARTICLE 2 – TERM AND TERMINATION
A. As applicable, the term of the Agreement (“Initial Term”) will be stated in the Agreement. Following the Initial Term, the A greement may be extended by written mutual agreement.
B. UC’s obligation to proceed is conditioned upon the appropriation of state, federal and other sources of funds not controlled by UC ("Funding"). UC will have the right to terminate the Agreement without damage, penalty, cost or further obligation in the eve nt that through no action or inaction on the part of UC, the Funding is withdrawn.
C. UC may, by written notice stating the extent and effective date thereof, terminate the Agreement for convenience in whole or in part, at any time with not less than the number of days’ notice stated elsewhere in the Agreement. As specified in the termination notice, UC will pay Supplier as full compensation the pro rata Agreement price for performance through the later of the date that (i) UC provided Supplier with notice of termination or (ii) Supplier’s provision of Goods and/or Services will terminate.
D. UC may by written notice terminate the Agreement for Supplier’s breach of the Agreement, in whole or in part, at any time, if Supplier refuses or fails to comply with the provisions of the Agreement, or so fails to make progress as to endanger performance and does not cure such failure within five (5) business days , or fails to supply the Goods and/or Services within the time specified or any written extension thereof. In such event, UC may pu rchase or otherwise secure Goods and/or Services and, except as otherwise provided herein, Supplier will be liable to UC for any excess costs UC incurs thereby.
ARTICLE 3 – PRICING, INVOICING METHOD, AND SETTLEMENT METHOD AND TERMS. Pricing is set forth in the Agreement or Purchase Order Number, and the amount UC is charged and responsible for shall not exceed the amount specified in the Agreement unless UC has given prior written approval . Unless otherwise agreed in writing by UC, Supplier will use the i nvoicing method and payment settlement method (and will extend the terms applicable to such settlement method) set forth in UC’s Supplier Invoicing, Terms & Settlement Matrix.
UC will pay Supplier, upon submission of acceptable invoices, for Goods and/or Services provided and accepted. Invoices must be itemized and reference the Agreement or Purchase Order number. UC will not pay shipping, packaging or handling expenses, unless specified in the Agreement or Purchase Order. Unless otherwise provided, freight is to be FOB destination. Any of Supplier’s expenses that UC agrees to reimburse will be reimbursed under UC’s Travel Policy, which may be found at https://policy.ucop.edu/doc/3420365. Where applicable, Supplier will pay all taxes imposed on Supplier in connection with its performance under the Agreement, including any federal, state and local income, sales, use, excise and other taxes or assessments . Notwithstanding any other provision to the contrary, UC will not be responsible for any fees, interest or surcharges Supplier wishes to impose.
ARTICLE 4 – INSPECTION. The Goods and/or Services furnished will be exactly as specified in the Agreement, f ree from all defects in Supplier's performance, design, workmanship and materials, and, except as otherwise provided in the Agreement, will be subjec t to inspection and test by UC at all times and places. If, prior to final acceptance, any Goods and/or Services furnished are found to be incomplete, or not as specified, UC may reject them, require Supplier to correct them at the sole cost of Supplier , or require provision of such Goods and/or Services at a reduction in price that is equitable under the circumstances. If Supplier is unable or refuses to correct such deficiencies within a time UC deems reasonable, UC may terminate the Agreement in whole or in part. Supplier will bear all risks as to DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
Revised 5/9/19
Terms and Conditions of Purchase
rejected Goods and/or Services and, in addition to any cost s for which Supplier may become liable to UC under other provisions of the Agreement, will reimburse UC for all transportation costs, other related costs incurred, or payments to Supplier in accordanc e with the terms of the Agreement for unaccepted Goods a nd/or Services and materials and supplies incidental thereto. Notwithstanding final acceptance and payment, Supplier will be liable for latent defects, fraud or such gross mistakes as amount to fraud.
ARTICLE 5 – ASSIGNED PERSONNEL; CHARACTER OF SERVICES
Supplier will provide the Services as an independent contractor and furnish all equipment, personnel and materiel sufficient to provide the Services expeditiously and efficiently, during as many hours per shift and shifts per week, and at such locations as UC may s o require.
Supplier will devote only its best-qualified personnel to work under the Agreement. Should UC inform Supplier that anyone providing the Services is not working to this standard, Supplier will immediately remove such personnel from providing Services and he or she will not again, without UC’s written permission, be assigned to provide Services. At no time will Supplier or Supplier’s employees, s ub-suppliers, agents, or assigns be considered employees of UC for any purpose, including but not limited to workers’ compensation provisions. Supplier shall not have the power nor right to bind or obligate UC, and Supplier shall not hold itself out as having such authority. Supplier shall be responsible to UC for all Services performed by Supplier’s employees, agents and subcontractors, including being responsible for ensuring payment of all unemployment, social security, payroll, contributions and other taxes with respect to such employees, agents a nd subcontractors.
ARTICLE 6 – WARRANTIES
In addition to the warrant ies set forth in Articles 11, 12, 17, 23, 24 , 25 and 26 herein, Supplier makes the following warranties. Supplier acknowledges that failure to comply with any of the warranties in the Agreement will constitute a material breach of the Agre ement and UC will have the right to terminate the Agreement without damage, penalty, cost or further obligation.
A. General Warranties . Supplier represents, warrants and covenants that: (i) Supplier is free to enter into this Agreement and that Supplier is not, and will not become, during the Term, subject to any restrictions that might restrict or prohibit Supplier from performing the Services or providing the Goods ordered hereunder ; (ii) Supplier will comply with all applicable laws, rules and regulations in performing Su pplier’s obligations hereunder; (iii) the Goods and/or Services shall be rendered with promptness and diligence and shall be executed in a workmanlike manner by competent personnel, in accordance with the prevailing industry standards; and if UC Appendix Data Security is NOT included:(iv) Supplier has developed a business interruption and disaster recovery program and is executing such program to assess and reduce the extent to which Supplier’s hardware, software and embedded systems may be susceptible to errors or failures in various crisis (or force majeure) situations; (v) if Supplier uses electronic syste ms for creating, modifying, maintaining, archiving, retrieving or transmitting any records, including test results that are requ ired by, or subject to inspection by an applicable regulatory authority, then Supplier represents and warrants that Supplier’s systems fo r electronic records are in compliance; and (vi) Supplier agrees that the Goods and/or Services furnished under the Agreem ent will be covered by the most favorable warranties Supplier gives to any customer for the same or substantially similar goods or services, or such other more favorable warranties as specified in the Agreement. The rights and remedies so provided are in addition to and do not limit any rights afforded to UC by any other article of the Agreement.
B. Permits and Licenses. Supplier agrees to procure all necessary permits or licenses and abide by all applicable laws, regulations and ordinances of the United Sta tes and of the state, territory and political subdivision or any other country in which the Goods and/or Services are provided.
C. Federal and State Water and Air Pollution Laws . Where applicable, Supplier warrants that it complies with the requirements in U C Business and Finance Bulletin BUS-56 (Materiel Management; Purchases from Entities Violating State or Federal Water or Air Pollution Laws). Consistent with California Government Code 4477, these requirements do not permit UC to contract with entities in violation of Federal or State water or air pollution laws.
D. Web Accessibility Requirements. As applicable to the Supplies and/or Services being provided under the Agreement, Supplier warrants that:
1. It complies with California and federal disabilities laws and regulations; The Goods and/or Services will conform to the accessibility requirements of WCAG 2.0AA.
2. Supplier agrees to promptly respond to and resolve any complaint regarding accessibility of its Goods and/or Services;
3. Within six (6) months of the signing of this Agreement, Supplier will complete the testing of the Goods and Services for leve l AA conformance with Web Content Accessibility Guidelines (WCAG) 2.0 and report those findin gs to the University. Provide the DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
Revised 5/9/19
Terms and Conditions of Purchase
source to whom the conformance should be submitted. In the event that testing results in findings of non -compliance, Supplier will provide a remediation plan to the University within two (2) months of completion of testing, and will use reasonable efforts to adhere to any remediation timelines provided to the University; and
4. The University and its Authorized User may abridge, modify, translate or create any derivative work based on the Goods and Services when necessary to allow Authorized Users with disabilities to access the Goods and Services.
E. General Accessibility Requirements. Supplier warrants that:
1. It will comply with California and federal disability laws and regulations;
2. Supplier will promptly respond to remediate to any identified accessibility defects in the Goods and Services to conform to WCAG
2.0 AA; and
3. Supplier agrees to promptly respond to and use reasonable efforts to resolve and remediate any complaint regarding accessibility of its Goods and/or Services.
F. Warranty of Quiet Enjoyment . Supplier warrants that Supplier has the right of Quiet Enjoyment in, and conveys the right of Quiet Enjoyment to UC for UC’s use of, any and all intellectual property that will be needed for Supplier’s provision, and UC’s use of, the Goods and/or Services provided by Supplier under the Agreement.
G. California Child Abuse and Neglect Reporting Act ("CANRA"). Where applicable, Supplier warrants that it complies with CANRA.
H. Debarment and Suspension . Supplier warrants that it is not presently debarred, suspended, proposed for debarment, or declared ineligible for award of federal contracts or participation in federal assistance programs or activities.
I. UC Trademark Licensing Code of Conduct. If the Goods will bear UC’s name (including UC campus names, abbreviations of these names, UC logos, UC mascots, or UC seals) or other trademarks owned by UC, Supplier warrants that it holds a valid license from UC a nd complies with the Trademark Licensing Code of Conduct policy, available at http://policy.ucop.edu/doc/3000130/TrademarkLicensing.
J. Outsourcing (Public Contract Code section 12147) Compliance . Supplier warrants that if the Agreement will displace UC employees, no funds paid u nder the Agreement will be used to train workers who are located outside of the United States, or plan to relocate outside the United States as part of the Agreement. Additionally, Supplier warrants that no work will be performed under the Agreement with workers outside the United States, except as described in Supplier’s bid. If Supplier or its subsupplier performs the Agreement with workers outside the United States during the life of the Agreement and Supplier did not describe such work in its bid, Supplier acknowledges and agrees that a) UC may terminate the Agreement without further obligation for noncompliance, and b) Supplier will forfeit to UC the amount UC paid for the percentage of work that was performed with workers outside the United States and not described in Supplier’s bid.
ARTICLE 7 – INTELLECTUAL PROPERTY, COPYRIGHT AND PATENTS A. Goods and/or Services Involving Work Made for Hire.
1. Unless UC indicates that the Goods and/or Services do not involve work made for hire, Supplier acknowledges and agrees that any deliverables provided to UC by Supplier in the performance of the Agreement, and any intellectual property rights therein , (hereinafter the "Deliverables") will be owned by UC. The Deliverables will be considered "work made for hire" under U.S. copyright law and all right, title, and interest to and in such Deliverables including, but not limited to, any and all copyr ights or trademarks, will be owned by UC. In the event that it is determined that UC is not the owner of such Deliverables under the "work made for hire" doctrine of U.S. copyright law, Supplier hereby irrevocably assigns to UC all right, title, and interest to and in such Deliverables and any copyrights or trademarks thereto.
2. The Deliverables must be new and original. Supplier must not use any pre-existing copyrightable or trademarked images, writings, or other proprietary materials (hereinafter "Pre-Existing Materials") in the Deliverables without UC’s prior written permission. In the event that Supplier uses any Pre -Existing Materials in the Deliverables in which Supplier has an ownership interest, UC is hereby granted, and will have, a non-exclusive, royalty-free, irrevocable, perpetual, paid-up, worldwide license (with the right to sublicense) to make, have made, copy, modify, make derivative works of, use, perform, display publicly, sell, and otherwise distribute such Pre-Existing Materials in connection with the Deliverables.
3. Whenever any invention or d iscovery is made or conceived by Supplier in the course of or in connection with the Agreement, Supplier will promptly furnish UC with complete information with respect thereto and UC will have the sole power to determine whether and where a patent applica tion will be filed and to determine the disposition of title to and all rights under any application or patent that may result.
4. Supplier is specifically subject to an obligation to, and hereby does, assign all right, title and interest in any such inte llectual property rights to UC as well as all right, title and interest in tangible research products embodying any such inventions whether DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
Revised 5/9/19
Terms and Conditions of Purchase
the inventions are patentable or not. Supplier agrees to promptly execute any additional documents or forms that UC ma y require in order to effectuate such assignment.
B. Goods and/or Services Not Involving Work Made for Hire.
1. If the Goods and/or Services do not involve work made for hire, and in the event that Supplier uses any Pre-Existing Materials in the Deliverables in which Supplier has an ownership interest, UC is hereby granted, and will have, a non -exclusive, royalty-free, irrevocable, perpetual, paid -up, worldwide license (with the right to sublicense) to make, have made, copy, modify, make derivative works of, use, perform, display publicly, sell, and otherwise distribute such Pre -Existing Materials in connection with the Deliverables.
2. The Deliverables must be new and original. Supplier must not use any Pre -Existing Materials in the Deliverables with out UC’s prior written permission.
3. Whenever any invention or discovery is made or conceived by Supplier in the course of or in connection with the Agreement, Supplier will promptly furnish UC complete information with respect thereto and UC will have the s ole power to determine whether and where a patent application will be filed and to determine the disposition of title to and all rights under any application or patent that may result.
4. Supplier is specifically subject to an obligation to, and hereby does, assign all right, title and interest in any such intellectual property rights to UC as well as all right, title and interest in tangible research products embodying any such inventions whether the inventions are patentable or not. Supplier agrees to prom ptly execute any additional documents or forms that UC may require in order to effectuate such assignment.
C. General. Should the Goods and/or Services become, or in Supplier’s opinion be likely to become, the subject of a claim of infringement of any patent, copyright, trademark, trade name, trade secret, or other proprietary or contractual right of any third party, Supplier will provide written notice to UC of the circumstances giving rise to such claim or likely claim. In the event that UC receives notice of a claim of infringement or is made a party to or is threatened with being made a party to any claim of infringement related to the Goods and/or Services, UC will provide Supplier with notice of such claim or threat. Following receipt of such notice, Supplier will either (at Supplier’s sole election) (i) procure for UC the right to continue to use the affected portion of the Goods and/or Services, or (ii) replace or otherwise modify the affected portion of the Goods and/or Services to make them non- infringing, or obtain a reasonable substitute product for the affected portion of the Goods and/or Services, provided that any replacement, modification or substitution under this paragraph does not effect a material change in the Goods and/or Services’ functionality. If none of the foregoing options is reasonably acceptable to UC, UC will have the right to terminate the Agreement without damage, penalty, cost or further obligation.
ARTICLE 8 – INDEMNITY
To the fullest extent permitted by law, Supplier will defend, indemnify, and hold harmless UC, its officers, employees, and agents, from and against all losses, expenses (including, without limitation, reasonable attorneys' fees and costs), damages, and liabilities of any kind resulting from or arising out of the Agreement, including the performance hereunder of Supplier, its officers, employees, agents, sub -suppliers, or anyone directly or indirectly employed by Supplier, or any person or persons under Supplier's direction and control, provided such loss es, expenses, damages and liabilities are due or claimed to be due to the acts or omissions of Supplier, its officers, employees, agents, sub- suppliers, or anyone directly or indirectly employed by Supplier, or any person or persons under Supplier's direction and control. UC agrees to provide Supplier with prompt notice of any such claim or action and to permit Supplier to defend any claim or action, and that UC will cooperate fully in such defense. UC retains the right to participate in the defense against any such claim or action, and the right to consent to any settlement, which consent will not unreasonably be withheld.
ARTICLE 9 – INSURANCE
Supplier, at its sole cost and expense, will insure its activities in connection with providing the Goods and/or Services and obtain, keep in force, and maintain the following insurance with the minimum limits set forth below, unless UC specifies otherwise:
A. Commercial Form General Liability Insurance (contractual liability included) with limits as follows:
1. Each Occurrence $ 1,000,000
2. Products/Completed Operations Aggregate $ 2,000,000 DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
Revised 5/9/19
Terms and Conditions of Purchase
3. Personal and Advertising Injury $ 1,000,000
4. General Aggregate $ 2,000,000
B. Business Automobile Liability Insurance for owned, scheduled, non -owned, or hired automobiles with a combined single limit of not less than one million dollars ($1,000,000) per occurrence. (Required only if Supplier drives on UC premises or transports UC employees, officers, invitees, or agents in the course of supplying the Goods and/or Services to UC.) C. If applicable, Professional Liability Insurance with a limit of two million dollars ($2,000,000) per occurrence or claim with an aggregate of not less than two million dollars ($2,000,000). If this insurance is written on a claims -made form, it will continue for three years following termination of the Agreement. The insurance will have a retroactive date of placement prior to or coinciding with the effective date of the Agreement.
D. Workers' Compensation as required by applicable state law and Employer’s Liability with limits of one million dollars ($1,000,000) per occurrence. Workers' Compensatio n as required by applicable state law and Employer’s Liability with limits of one million dollars ($1,000,000) per occurrence.
E. If applicable, Supplier Fidelity Bond or Crime coverage for the dishonest acts of its employees in a minimum amount of one mi llion dollars ($1,000,000). Supplier will endorse such policy to include a “Regents of the University of California Coverage” or “J oint Payee Coverage” endorsement. UC and, if so requested, UC’s officers, employees, agents and sub-suppliers will be named as "Loss Payee, as Their Interest May Appear” in such Fidelity Bond.
F. Additional other insurance in such amounts as may be reasonably required by UC against other insurable risks relating to performance.
If the above insurance is written on a claims-made form, it will continue for three years following termination of the Agreement. The insurance will have a retroactive date of placement prior to or coinciding with the effective date of the Agreement. If the a bove insurance coverage is modified, changed or cancelled, Supplier will provide UC with not less than fifteen (15) days’ advance written notice of such modification, change, or cancellation, and will promptly obtain replacement coverage that complies with this Article.
G. The coverages referred to under A and B of this Article must include UC as an additional insured. It is understood that the c overage and limits referred to under A, B and C of this Article will not in any way limit Supplier’s liability. Supplier will furnish UC with certificates of insurance (and the relevant endorsement pages) evidencing compliance with all requirements prior to commencing work under the Agreement. Such certificates will:
1. Indicate that The Regents of the University of California has been endorsed as an additional insured for the coverage referred to under A and B of this Article. This provision will only apply in proportion to and to the extent of the negligent acts or omi ssions of Supplier, its officers, agents, or employees.
2. Include a provision that the coverage will be primary and will not participate with or be excess over any valid and collectible insurance or program of self-insurance carried or maintained by UC.
ARTICLE 10 – USE OF UC NAME AND TRADEMARKS
Supplier will not use the UC name, ab b r e viat io n o f t h e UC n am e , trade names and/or trademarks (i.e., logos and seals) or any derivation thereof, in any form or manner in advertisements, reports, or other information released to the public, or place the UC name, abbreviations, trade names and/or trademarks or any derivation thereof on any consumer goods, products, or services for sale or distribution to the public, without U C ’ s prior written approval. Supplier agrees to comply at all times with California Education Code Section 92000.
ARTICLE 11 – FEDERAL FUNDS
Supplier who supplies Goods and/or S ervices certifies and represents its compliance with the following clauses, as applicable. Supplier shall promptly notify UC of any change of status w ith regard to these certifications and representations. These certifications and representations are material statements upon which UC will rely.
A. For commercial transactions involving funds on a federal contract (federal awards governed by the FAR), the following provisions apply, as applicable:
i. FAR 52.203-13, Contractor Code of Business Ethics and Conduct; ii. FAR 52.203-17, Contractor Employee Whistleblower Rights and Requirement to Inform Employees of Whistleblower Rights; iii. FAR 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements; iv. FAR 52.219-8, Utilization of Small Business Concerns; v. FAR 52.222-17, Non-displacement of Qualified Workers; DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
Revised 5/9/19
Terms and Conditions of Purchase
vi. FAR 52.222-21, Prohibition of Segregated Facilities; vii. FAR 52.222-26, Equal Opportunity;
viii. FAR 52.222-35, Equal Opportunity for Veterans;
ix. FAR 52.222-36, Equal Opportunity for Workers with Disabilities; x. FAR 52.222-37, Employment Reports on Veterans;
xi. FAR 52.222-40, Notification of Employee Rights Under the National Labor Relations Act; xii. FAR 52.222-41, Service Contract Labor Standards;
xiii. FAR 52.222-50, Combating Trafficking in Persons;
xiv. FAR 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment - Requirements;
xv. FAR 52.222 -53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services - Requirements;
xvi. FAR 52.222-54, Employment Eligibility Verification; xvii. FAR 52.222-55, Minimum Wages Under Executive Order 13658; xviii. FAR 52.222-62, Paid Sick Leave under Executive Order 13706; xix. FAR 52.224-3, Privacy Training;
xx. FAR 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations; and xxi. FAR 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels.
B. For non-commercial transactions involving funds on a federal contract, the UC Appendix titled ‘Federal Government Contracts Special terms and Conditions (Non-Commercial Items or Services)’ and located at www.ucop.edu/procurement-services/policies- forms/index.html is hereby incorporated herein by this reference.
C. For transactions involving funds on a federal grant or cooperative agreement (federal awards governed by eCFR Title 2, Subtitle A, Chapter II, Part 200) the following provisions apply, as applicable:
i. Rights to Inventions. If Supplier is a small business firm or nonprofit organization, and is providing experimental, development, or research work under this transaction, Supplier must comply with the requirements of 3 CFR Part 401, “Rights to Inventions Made by nonprofit Organizations and Small Business Firms Under Government Grants, Contracts, and Cooperative Agreements”. ii. Clean Air Act. Supplier agrees to comply with all applicable standards, orders or regulations issued pursuant to the Clean Air Act (42 U.S.C. 7401 -7671q) and the Federal Water Pollution Co ntrol Act as amended (33 U.S.C. 1251 -1387). Violations must be reported to the Federal awarding agency and the Regional Office of the Environmental Protection Agency (EPA). iii. Byrd Anti -Lobbying. Supplier certifies that it will not, and has not used Federal a ppropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant or any other award covered by 31 U.S.C. 1352.
iv. Procurement of Recovered Materials. If Supplier is a state agency or agency of a political subdivision of a state, then Supplier must comply with section 6002 of the Solid Waste Disposal Act, as amended by the Resource Conservation and Recovery Act.
D. In these provisions, the term "contractor" as used therein will refer to Supplier, and the terms “Government” or “Contracting Officer” as used therein will refer to UC. Where a purchase of items is for fulfillment of a specific U.S. Government prime or subcontract, additional information and/or terms and conditions m ay be inclu ded in an attached supplement. By submitting an invoice to UC, Supplier is representing to UC that, at the time of submission:
i. Neither Supplier nor its principals are presently debarred, suspended, or proposed for debarment by the U.S. government (see FAR 52.209-6);
ii. Supplier has filed all compliance reports required by the Equal Opportunity clause (see FAR 52.222-22); and iii. Any Supplier representations to UC about U.S. Small Business Administration or state and local classifications, including but not limited to size standards, ownership, and control, are accurate and complete. iv. Byrd Anti-Lobbying. Supplier certifies that it will not, and has not used Federal appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
Revised 5/9/19
Terms and Conditions of Purchase
employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant or any other award covered by 31 U.S.C. 1352.
ARTICLE 12 – EQUAL OPPORTUNITY AFFIRMATIVE ACTION
Supplier will abide by the requirements set forth in Executive Orders 11246 and 11375. Where applicable, Supplier will comply with 41 CFR §§ 60-1.4(a), 60-300.5(a) and 60-741.5(a), incorporated by reference with this statement: “This contractor and subcontractor shall abide by the requirements of 41 CFR §§ 60 -1.4(a), 60-300.5(a) and 60 -741.5(a). These regulations prohibit discrimination against qualified individuals based on their status as protected veterans or individuals with disabilities, and prohibit discrimination against all individuals based on their race, color, religion, sex, sexual orientation, gender identity, or national origin. Moreover, these regulations require that covered prime contractors and subcontractors take affirmative action to employ and advance in employment individuals without regard to race, color, religion, sex, sexual orientation, gender identity, national origin, protected veteran status or disability.” With respect to activities occurring in the State of California, Supplie r agrees to adhere to the California Fair Employment and Housing Act. Supplier will provide UC on request a breakdown of its labor force by groups as specified by UC, and will discuss with UC its policies and practices relating to its affirmative action programs. Supplier will not maintain or provide facilities for employees at any establishment under its control that are segregated on a basis prohibited by federal law. Separate or single -user restrooms and necessary dressing or sleeping areas must be provided, however, to ensure privacy.
ARTICLE 13 – LIENS
Supplier agrees that upon UC’s request, Supplier will submit a sworn statement setting forth the work performed or material furnished by sub-suppliers and material men, and the amount due and to become due to each, and that before the final payment called for under the Agreement, will upon UC’s request submit to UC a complete set of vouchers showing what payments have been made for such work performed or material furnished. Supplier will promptly notify UC in writing, of any claims, demands, causes of action, liens or suits brought to its attention that arise out of the Agreement. UC will not make final payment until Supplier, if required, delivers to U C a complete release of all liens arising out of t he Agreement, or receipts in full in lieu thereof, as UC may require, and if required in either case, an affidavit that as far as it has knowledge or information, the receipts include all the labor and materials for which a lien c ould be filed; but Supplier may, if any sub-supplier refuses to furnish a release or receipt in full, furnish a bond satisfactory to UC to indemnify it against any claim by lien or otherwise. If any lien or claim remains unsatisfied after all payments are made, Supplier will refun d to UC all monies that UC may be compelled to pay in discharging such lien or claim, including all costs and reasonable attorneys' fees.
ARTICLE 14 – PREMISES WHERE SERVICES ARE PROVIDED
A. Cleaning Up . Supplier will at all times keep UC premises where th e Services are performed and adjoining premises free from accumulations of waste material or rubbish caused by its employees or work of any of its sub-suppliers, and, at the completion of the Services; will remove all rubbish from and about the premises an d all its tools, scaffolding, and surplus materials, and will leave the premises "broom clean" or its equivalent, unless more exactly specified. In case of dispute between Supplier and its sub -suppliers as to responsibility for the removal of the rubbish, or if it is not promptly removed, UC may remove the rubbish and charge the cost to Supplier.
B. Environmental, Safety, Health and Fire Protection . Supplier will take all reasonable precautions in providing the Goods and Services to protect the health and sa fety of UC employees and members of the public and to minimize danger from all hazards to life and property, and will comply with all applicable environmental protection, health, safety, and fire protection regulations and requirements (including reporting requirements). In the event that Supplier fails to comply with such regulations and requirements, UC may, without prejudice to any other legal or contractual rights of UC, issue an order stopping all or any part of the provision of the Goods and/or Services; thereafter a start order for resumption of providing the Goods and/or Services may be issued at UC’s discretion.
Supplier will not be entitled to make a claim for extension of time or for compensation or damages by reason of or in connection with such stoppage. Supplier will have sole responsibility for the safety of all persons employed by Supplier and its sub -suppliers on UC premises, or any other person who enters upon UC premises for reasons relating to the Agreement. Supplier will at all times maintain good order among its employees and all other persons who come onto UC's premises at Supplier's request and will not engage an y unfit or unskilled person to provide the Goods and/or Services. Supplier will confine its employees and all other perso ns who come onto UC's premises at Supplier's request or for reasons relating to the Agreement and its equipment to that portion of UC's premises where the Services are to be provided or to roads leading to and from such work sites, and to any other area wh ich UC may permit DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
Revised 5/9/19
Terms and Conditions of Purchase
Supplier to use. Supplier will take all reasonable measures and precautions at all times to prevent injuries to or the death of any of its employees or any other person who enters upon UC premises at Supplier’s request. Such measures and precautions will include, but will not be limited to, all safeguards and warnings necessary to protect workers and others against any conditions on the pre mises that could be dangerous and to prevent accidents of any kind whenever the Goods and/or Services are being provided in proximity to any moving or operating machinery, equipment or facilities, whether such machinery, equipment or facilities are the property of or are being operated by, Supplier, its sub-suppliers, UC or other persons. To the extent compliance is required, Supplier will comply with all relevant UC safety rules and regulations when on UC premises.
C. Tobacco-free Campus . UC is a tobacco-free institution. Use of cigarettes, cigars, oral tobacco, electronic cigarettes and all other tobacco products is prohibited on all UC owned or leased sites.
ARTICLE 15 – LIABILITY FOR UC - FURNISHED PROPERTY
Supplier assumes complete liability for any materials UC furnishes to Supplier in connection with the Agreement and Supplier agrees to pay for any UC materials Supplier damages or otherwise is not able to account for to UC's satisfaction. UC furnishing to Supplier any materials in connection with the Agreement will not, unless otherwise expressly provided in writing by UC, be construed to ve st title thereto in Supplier.
ARTICLE 16 – COOPERATION
Supplier and its sub -suppliers, if any, will cooperate with UC and other suppliers and will so provide the Services that other cooperating suppliers will not be hindered, delayed or interfered with i n the progress of their work, and so that all of such work will be a finished and complete job of its kind.
ARTICLE 17 – ADDITIONAL TERMS APPLICABLE TO THE FURNISHING OF GOODS The terms in this Article have special application to the furnishing of Goods:
A. Price Decreases. Supplier agrees immediately to notify UC of any price decreases from its suppliers, and to pass through to UC any price decreases.
B. Declared Valuation of Shipments. Except as otherwise provided in the Agreement, all shipments by Supplier under the Agreement for UC's account will be made at the maximum declared value applicable to the lowest transportation rate or classification and the bill of lading will so note.
C. Title. Title to the Goods purchased under the Agreement will pass directly from Supplier to UC at the f.o.b. point shown, or as otherwise specified in the Agreement, subject to UC’s right to reject upon inspection.
D. Changes. Notwithstanding the terms in Article 34, Amendments, UC may make changes within the general scope of the Agreement in drawings and specifications for specially manufactured Goods, place of delivery, method of shipment or packing of the Agreement by giving notice to Supplier and subsequently confirming such changes in writing. If such changes affect the cost of or the time required for performance of the Agreement, UC and Supplier will agree upon an equitable adjustment in the price and/or delivery terms.
Supplier may not make changes without UC’s written approval. Any claim of Supplier for an adjustm ent under the Agreement must be made in writing within thirty (30) days from the date Supplier receives notice of such change unless UC waives this condit ion in writing. Nothing in the Agreement will excuse Supplier from proceeding with performance of the Agreement as changed hereunder.
Supplier may not alter or misbrand, within the meaning of the applicable Federal and State laws, the Goods furnished.
E. Forced, Convict and Indentured Labor. Supplier warrants that no foreign-made Goods furnished to UC pursuant to the Agreement will be produced in whole or in part by forced labor, convict labor, or indentured labor under penal sanction. If UC determines that Supplier knew or should have known that it was breaching this warranty, UC may, in addition to termin ating the Agreement, remove Supplier from consideration for UC contracts for a period not to exceed one year. This warranty is in addition to any applicable warranties in Articles 6 and 11.
F. Export Control. If any of the Goods is export -controlled under the International Traffic in Arms Regulations (22 CFR §§ 120 -130), the United States Munitions List (22 CFR § 121.1), or Export Administration Regulations (15 CFR §§ 730-774) 500 or 600 series, or controlled on a military strategic goods list, Supplier agr ees to provide UC (the contact listed on the Purchase Order) with written notification that identifies the export-controlled Goods and such Goods’ export classification.
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
Revised 5/9/19
Terms and Conditions of Purchase
ARTICLE 18 – CONFLICT OF INTEREST
Supplier affirms that, to the best of Supplier’s kn owledge, no UC employee who has participated in UC’s decision -making concerning the Agreement has an “economic interest” in the Agreement or Supplier. A UC employee’s “economic interest” means:
A. An investment worth $2,000 or more in Supplier or its affiliate; B. A position as director, officer, partner, trustee, employee or manager of Supplier or its affiliate; C. Receipt during the past 12 months of $500 in income or $440 in gifts from Supplier or its affiliate; or D. A personal financial benefit from the Agreement in the amount of $250 or more.
In the event of a change in these economic interests, Supplier will provide written notice to UC within thirty (30) days afte r such change, noting such changes. Supplier will not be in a reporting relationship to a UC employee who is a near relative, nor will a near relative be in a decision making position with respect to Supplier.
ARTICLE 19 – AUDIT REQUIREMENTS
The Agreement, and any pertinent records involving transactions relating to this Agreement, is subject to the examination and audit of the Auditor General of the State of California or Comptroller General of the United States or designated Federal authority for a period of up to five (5) years after final payment under the Agreement. UC, a nd if the underlying grant , cooperative agreement or federal contract so provides, the other contracting Party or grantor (and if that be the United States or an instrumentality thereof, then the Comptroller General of the United States) will have access t o and the right to examine Supplier’s pertinent books, documents, papers, and records involving transactions and work related to the Agreement until the expiration of five (5) years after final payment under the Agreement. The examination and audit will b e confined to those matters connected with the performance of the Agreement, including the costs of administering the Agreement.
ARTICLE 20 – PROHIBITION ON UNAUTHORIZED USE OR DISCLOSURE OF CONFIDENTIAL INFORMATION Supplier agrees to hold UC’s Confidential Information , and any information derived therefrom, in strict confidence. Confidential Information shall be defined as any information disclosed by UC to Supplier for the purposes of providing the Good and/or Services which is (i) marked as “Confidential” at the time of disclosure; (ii) disclosed orally, identified at the time of such oral disclosure as confidential, and reduced to writing as “Confidential” within thirty (30) days of such oral disclosure; and (iii) if not marked as “Confidential,” information that would be considered by a reasonable person in the relevant field to be confidential given its content and the circumstances of its disclosure. Confidential Information will not include information that: (i) Supplier can demonstrate by written records was known to Supplier prior to the effective date of the Agreement; ( ii) is currently in, or in the future enters, the public domain other than through a breach of the Agreement or through other acts or omissions of Supplier; (iii) is obtained lawfully from a third party; or (iv) is disclosed under the California Public Records Act or legal process.
Supplier will not access, use or disclose Confidential Information other than to carry out the purposes for which UC disclosed the Confidential Information to Supplier, except as permitted or required by applicable law, or as otherwise authorized in writing by UC prior to the disclosure. Supplier shall have the limited right to disclose UC’s Confidential Information to Supplier’s employees provided that: (i) Supplier shall disclose only such UC’s Confidential Information as is n ecessary for the Supplier to perform its obligations under this Agreement; (ii) such employees have been informed of the confidential nature of such information; and (iii) such employees have agreed in writing to be bound by confidentiality obligations at least as stringent as those set forth in this Agreement. Supplier shall be liable for any breach of this Agreement by its employees. For avoidance of doubt, this provision prohibits Supplier from using for its own benefit Confidential Information and any information derived therefrom. If Supplier is required by a court of competent jurisdiction or an administrative body to disclose Confidential Information, Supplier will notify UC in writing immediately upon receiving notice of such requirement and prior to any such disclosure (unless Supplier is prohibited by law from doing so), to give UC an opportunity to oppose or otherwise respond to such disclosure. To the extent Supplier is still required to make such a disclosure, Supplier will give UC prompt written notice of such event and will furnish only that portion that is legally required and will exercise all reasonable efforts to obtain reliable assurance that confidential treatment will be afforded to the Confidential Information. Supplier’s transmission, transportation or storage of Confidential Information outside the United States, or access of Confidential Information from outside the United States, is prohibited except with prior written authorization by UC. UC’s Appendix – Data Security, Appendix – HIPAA Business Associate, and/or Appendix – General Data Protection Regulation will control in the event that one or both appendices is incorporated into the Agreement and conflicts with the provisions of this Article.
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
Revised 5/9/19
Terms and Conditions of Purchase
Supplier acknowledges that remedies at law would be inadequate to protect UC against any actual or threatened breach of this Section by Supplier, and, without prejudice to any other rights and remedies otherwise available to UC, Supplier agrees to the granting of injunctive relief in UC’s favor without proof of actual damages.
ARTICLE 21 – UC WHISTLEBLOWER POLICY
UC is committed to conducting its affairs in compliance with the law, and has established a process for reporting and investigating suspected improper governmental activities. Please visit http://www.ucop.edu/uc-whistleblower/ for more information.
ARTICLE 22 – SUSTAINABLE PROCUREMENT GUIDELINES
Supplier will conduct business using environmentally, socially, and economically sustainable products and services (defined as products and services with a lesser or reduced effect on human health and the environment, and which generate benefits to the Universi ty as well as to society and the economy, while remaining within the carrying capacity of the environ ment), to the maximum possible extent consistent with the Agreement, and with the University of California Sustainable Practices Policy ( https://policy.ucop.edu/doc/3100155) and the University of California Sustainable Procurement Guidelines:
(https://www.ucop.edu/procurement-services/_files/sustainableprocurementguidelines.pdf).
In accordance with the University of California Sustainable Practices Policy, Supplier will adhere to the following requireme nts and standards, as applicable. Supplier acknowledges that failure to comply with any of the sustainability standards and require ments in the Agreement will constitute a material breach of the Agreement and UC will have the right to terminate the Agreement without da mage, penalty, cost or further obligation.
A. Sustainability Marketing Standards. Supplier sustainability related claims, where applicable, must meet University of California recognized certifications and standards set forth in the UC Sustainable Procurement Guidelines and/or meet the standards of Federal Trade Commission’s (FTC) Green Guides.
B. Electronic Transfer of Supplier Information. Suppliers, when interacting with the University, shall be prohibited from providing hard copies of presentations, marketing material, or other informational materials. Suppliers will be required to present all information in electronic format that is easily transferable to University staff. Materials may be provided in hard copy or physical format if specifically required or requested by a UC representative.
C. Packaging Requirements. All packaging must be compliant with the Toxics in Packaging Prevention Act (AB 455) and must meet all additional standards and requirements set forth in the UC Sustainable Practices Policy. In addition, the University requires that all packaging meet at least one of the criteria listed below:
a. Uses bulk packaging;
b. Uses reusable packaging (e.g. totes reused by delivery service for next delivery); c. Uses innovative packaging that reduces the weight of packaging, reduces packaging waste, or utilizes packaging that is a component of the product;
d. Maximizes recycled content and/or meets or exceeds the minimum post-consumer content level for packaging in the U.S.
Environmental Protection Agency Comprehensive Procurement Guidelines; e. Uses locally recyclable or certified compostable material.
D. Expanded Polystyrene (EPS) Ban. No EPS shall be used in foodservice facilities for takeaway containers. By 2020, the University will be prohibited from procuring Goods containing, or that are provided in packaging containing, Expanded Polystyrene (EPS) other than that utilized for laboratory supply or medical packaging and products where no functional alternatives exist.
E. E-Waste Recycling Requirements. All recyclers of University of California electronic equipment must be e-Steward certified by the Basel Action Network (BAN) or R2 Standard certified.
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
Revised 5/9/19
Terms and Conditions of Purchase
Hosted and Punch -out Catalog Requirements . Suppliers enabled with eProcurement hosted catalog functionality must clearly identify products with UC-recognized certifications, as defined by the UC Sustainable Procurement Guidelines, in both hosted and punchout catalog e-procurement environments.
ARTICLE 23 – PATIENT PROTECTION AND AFFORDABLE CARE ACT (PPACA) EMPLOYER SHARED RESPONSIBILITY If the Services involve Supplier furnishing UC with temporary or supplementary staffing, Supplier warrants that:
A. If Supplier is an Applicable Large Employer (as defined under Treasury Regulation Section 54.4980H-1(a)(4)):
1. Supplier offers health coverage to its full-time employees who are performing Services for UC;
2. Supplier’s cost of enrolling such employees in Supplier’s health plan is factored into the fees for the Services; and
3. The fees for the Services are higher than what the Services would cost if Supplier did not offer health coverage to such full -time employees.
B. If Supplier is not an Applicable Large Employer (as defined above):
1. Supplier offers group health coverage to its full-time employees who are performing Services for UC and such coverage is considered Minimum Essential Coverage (as defined un der Treasury Regulation Section 1 -5000A-2) and is Affordable (as defined under Treasury Regulation Section 54.4980H-5(e)); or
2. Supplier’s full-time employees who are performing services for UC have individual coverage and such coverage satisfies the PPACA requirements for mandated individual coverage.
Supplier acknowledges that UC is relying on these warranties to ensure UC’s compliance with the PPACA Employer Shared Respons ibility provision.
ARTICLE 24 - PREVAILING WAGES
Unless UC notifies Supplier that the Services are not subject to prevailing wage requirements, Supplier will comply, and will ensure that all sub-suppliers comply, with California prevailing wage provisions, including but not limited to those set forth in Labor Code sect ions 1770, 1771, 1771.1, 1772, 1773, 1773.1, 1774, 1775, 1776, 1777.5, and 1777.6. For purposes of the Agreement, the term “sub -supplier” means a person or firm, of all tiers, that has a contract with Supplier or with a sub -supplier to provide a portion of the Services . The term sub - supplier will not include suppliers, manufacturer s, or distributors. Specifically, and not by way of limitation, if apprenticable occupations are involved in providing the Services, Supplier will be responsible for ensuring that Supplier and any sub-suppliers comply with Labor Code Section 1777.5. Supplier and sub -supplier may not provide the Services unless currently registered and qualified to perform public work pursuant to Labor Code Section 1725.5 and 1771.1. Notwithstanding the foregoing provisions, Supplier will be solely responsible for tracking and ensuring proper payment of prevailing wages regardless if Services are partially or wholly subject to prevailing wage req uirements. In every instance, Supplier will pay not less than the UC Fair Wage (defined as $13 per hour as of 10/1/15, $14 per hour as of 10/1/16, and $15 per hour as of 10/1/17) for Services being performed at a UC Location (defined as any location owned or leased by UC).
The California Department of Industrial Relations (DIR) has ascertained the general prevailing per diem wage rates in the locality in which the Services are to be provided for each craft, classification, or type of worker required to provide the Services. A copy o f the general prevailing per diem wage rates will be on file at each UC Location’s procurement office, and will be made available to any interested party upon request. Supplier will post at any job site:
A. Notice of the general prevailing per diem wage rates, and B. Any other notices required by DIR rule or regulation.
By this reference, such notices are made part of the Agreement. Supplier will pay not less than the prevailing wage rates, as specified in the schedule and any amendments thereto, to all workers employed by Suppl ier in providing the Services. Supplier will cause all subcontracts to include the provision that all sub-suppliers will pay not less than the prevailing rates to all workers employed by such sub- suppliers in providing the Services. The Services are subj ect to compliance monitoring and enforcement by the DIR. Supplier will forfeit, as a penalty, not more than $200 for each calendar day or portion thereof for each worker that is paid less than the prevaili ng rates as determined by the DIR for the work or craft in which the worker is employed for any portion of the Services provided by Supplier or any sub-supplier. The amount of this penalty will be determined pursuant to applicable law. Such forfeiture amounts may be deducted from the amounts due under th e Agreement. If there are insufficient funds remaining in the amounts due under the Agreement, Supplier will DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
Revised 5/9/19
Terms and Conditions of Purchase
be liable for any outstanding amount remaining due. Supplier will also pay to any worker who was paid less than the prevailing wage rate for the w ork or craft for which the worker was employed for any portion of the Services, for each day, or portion thereof, for which t he worker was paid less than the specified prevailing per diem wage rate, an amount equal to the difference between the specified prevailing per diem wage rate and the amount which was paid to the worker. Review of any civil wage and penalty assessment will be made pursuant to California Labor Code section 1742.
ARTICLE 25 – FAIR WAGE/FAIR WORK
If the Agreement is for Services that will be performed at one or more UC Locations, does not solely involve furnishing Goods, and are not subject to extramural awards containing sponsor-mandated terms and conditions, Supplier warrants that it is in compliance with applicable federal, state and local working conditions requirements, including but not limited to those set forth in Articles 11, 12 and 14 herein, a nd that Supplier pays its employees performing the Services no less than the UC Fair Wage. Supplier agrees UC may conduct such UC Fair Wage/Fair Work interim compliance audits as UC reasonably requests, as determined in UC’s sole discretion . Supplier agrees to post UC Fair Wage/Fair Work notices, in the form supplied by UC, in public areas (such as break rooms and lunch rooms) fre quented by Supplier employees who perform Services.
For Services that exceed $100,000 annually and are not subject to prevailing wage requirements, Supplier will, a) at Supplier’s expense, provide an annual independent verification performed by a licensed public accounting firm (independent accountant) or the Supplier’s independent internal audit department (http://na.theiia.org/standards-guidance/topics/Pages/Independence-and-Objectivity.aspx) in compliance with UC’s required verification standards and procedures, concerning Supplier’s compliance with this provision, and b) ensure that in the case of a UC interim audit, its independent accountant/independent internal auditor makes available to UC its UC Fair Wage/Fair Work work papers for the most recent verification period. Supplier agrees to provide UC with a UC Fair Wage/Fair Work verification annually, in a form acceptable to UC, no later than ninety days after each one-year anniversary of the agreement’s effective date, for the twelve months immediately preceding the anniversary date. All Supplier FW/FW compliance resources available here:
https://www.ucop.edu/procurement-services/for-suppliers/fwfw-resources-suppliers.html.
ARTICLE 26 – MEDICAL DEVICES
This Article applies when the Goods and/or Services involve UC purchasing or leasing one or more medical devices from Supplier, or when Supplier uses one or more medical devices in providing Goods and/or Services to UC.
Medical Device as used herein will have the meaning provided by the U.S. Food and Drug Administration (“FDA”) and means an instrument, apparatus, implement, machine, contrivance, implant, in vitro reagent, or other similar or related article, including a compo nent part, or accessory which is: (i) recognized in the official National Formulary, or the United States Pharmacopoei a, or any supplement to them; (ii) intended for use in the diagnosis of disease or other conditions, or in the cure, mitigation, treatment, or prevention of dis ease, in man or other animals, or (iii) intended to affect the structure or any function of the body of man or other animals, and which does not achieve any of its primary intended purposes through chemical action within or on the body of man or other animals and which is not dependent upon being metabolized for the achievement of any of its primary intended purposes.
Supplier warrants that prior to UC’s purchase or lease of any Medical Device or Supplier’s use of any Medical Device in provi ding Goods and/or Services hereunder, Supplier will: (i) perform security testing and validation for each such Goods and/or Services or Medical Device, as applicable; (ii) perform a security scan by an anti-virus scanner, with up-to-date signatures, on any software embedded within any Goods and/or Services or Medical Device, as applicable, in order to verify that the software does not contain any known viruses or malware; (iii) conduct a vulnerability scan encompassing all ports and fuzz testing; and (iv) provide UC with reports for (i) – (iii). Supplier warrants that all security testing performed by Supplier covers all issues noted in the “SANS WE TOP 25” and/or “OWASP Top 10” documentation.
Throughout Supplier’s performance of this Agreement, Supplier will provide UC with reasonably up-to-date patches, firmware and security updates for any Medical Device provid ed to UC, and any other Medical Device used in the course of providing Services, as applicable. All such patches and other security updates will be made available to UC within thirty (30) days of its commercial release or as otherwise recommended by Supplier or Supplier’s sub-supplier, whichever is earlier.
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
Revised 5/9/19
Terms and Conditions of Purchase
Supplier warrants that all software and installation media not specifically required for any Medical Device used by Supplier or Goods and/or Services delivered to UC under this Agreement as well as fil es, scripts, messaging services and data will be removed from all such Goods and/or Services or Medical Device following installation, and that all hardware ports and drives not required for use or oper ation of such Goods and/or Services or Medical Device will be disabled at time of installation. In addition, Medical Devices must be configured so that only Supplier-approved applications will run on such Medical Devices.
Supplier agrees that UC may take any and all actions that it, in its sole discretion, deems necessary to address, mitigate an d/or rectify any real or potential security threat, and that no such action, to the extent such action does not compromise device c ertification, will impact, limit, reduce or negate Supplier’s warranties or any of Supplier’s other obligations hereunder.
Supplier warrants that any Medical Device provided to UC, and any other Medical Device used in the course of providing such Goods and/or Services, meet and comply with all cyber -security guidance and similar standards promulgated by the FDA and any other applicable regulatory body.
If the Goods and/or Services entail provision or use of a Medical Device, Supplier will provide UC with a completed Manufacturer Disclosure Statement for Medical Device Security (MDS2) form for each such Medical Device before UC is obligated to purchase or lease such Medical Device or prior to Supplier’s use of such device in its performance of Services. If Supplier provides an MDS2 form to UC concurrently with its provision of Goods and/or Services, UC will have a reasonable period of time to review such MDS2 form, and if the MDS2 fo rm is unacceptable to UC, then UC in its sole discretion may return the Goods or terminate the Agreement with no further obligation to Supplier.
ARTICLE 27 – FORCE MAJEURE
Neither Party will be liable for delays due to causes beyond the Party’s control (including, but not restricted to, war, civil disturbances, earthquakes, fires, floods, epidemics, quarantine restrictions, freight embargoes, and unusually severe weather).
ARTICLE 28 – ASSIGNMENT AND SUBCONTRACTING
Except as to any payment due hereunder, Supplier may not assign or subcontract the Agreement without UC’s writte n consent. In case such consent is given, the assignee or subcontractor will be subject to all of the terms of the Agreement.
ARTICLE 29 – NO THIRD-PARTY RIGHTS
Nothing in the Agreement, express or implied, is intended to make any person or entity that is not a signer to the Agreement a third-party beneficiary of any right created by this Agreement or by operation of law.
ARTICLE 30 – OTHER APPLICABLE LAWS
Any provision required to be included in a contract of this type by any applicable and valid federal, state or local law, ordinance, rule or regulations will be deemed to be incorporated herein.
ARTICLE 31 – NOTICES
A Party must send any notice required to be given under the Agreement by overnight delivery or by certified mail with return receipt requested, to the other Party’s representative at the address specified by such Party.
ARTICLE 32 – SEVERABILITY
If a provision of the Agreement becomes, or is determined to be, illegal, invalid, or unenf orceable, that will not affect the legality, validity or enforceability of any other provision of the Agreement or of any portion of the invalidated provision that remains legal, valid, or enforceable.
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
Revised 5/9/19
Terms and Conditions of Purchase
ARTICLE 33 – WAIVER
Waiver or non-enforcement by either Party of a provision of the Agreement will not constitute a waiver or non -enforcement of any other provision or of any subsequent breach of the same or similar provision.
ARTICLE 34 – AMENDMENTS
The Parties may make changes in the Goods and/or Services or otherwise ame nd the Agreement, but only by a writing signed by both Parties’ authorized representatives.
ARTICLE 35 – GOVERNING LAW AND VENUE
California law will control the Agreement and any documen t to which it is appended. The exclusive jurisdiction and venue for any and all actions arising out of or brought under the Agreement is in a state court of competent jurisdiction, situated in the county i n the State of California in which the UC Location is located or, where the procurement covers more than one UC Location, the exclusive venue is Alameda County, California.
ARTICLE 36 – SUPPLIER TERMS
Any additional terms that Supplier includes in an order form or similar document will be of no force and effect, unless UC expressly agrees in writing to such terms.
ARTICLE 37 – SURVIVAL CLAUSE
Upon expiration or termination of the Agreement, the following provisions will survive: WARRANTIES; INTELLECTUAL PROPERTY, COPYRIGHT AND PATENTS; INDEMNITY; USE OF UC NAMES AND TRADEMARKS; LIABILITY FOR UC -FURNISHED PROPERTY; COOPERATION; TERMS APPLICABLE TO THE FURNISHING OF GOODS; AUDIT REQUIREMENTS; PROHIBITION ON UNAUTHORIZED USE OR DISCLOSURE OF CONFIDENTIAL INFORMATION; GOVERNING LAW AND VENUE, and, to the exte nt incorporated into the Agreement, the terms of the APPENDIX–DATA SECURITY, APPENDIX–BUSINESS ASSOCIATES, and/or APPENDIX – GENERAL DATA PROTECTION REGULATION.
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F UCOP Agreement #2020002144 Page 1 of 5
ATTACHMENT A TO PURCHASING AGREEMENT #2020002144
STATEMENT OF WORK
This Statement of Work (“SOW”) is issued pursuant to Purchasing Agreement #2020002144 dated April 15th, 2020 between UC and Supplier (“Agreement”).
1. Flooring Products & Services at the University of California Products and services provided to the University shall meet all requirements established under the Category Specifications and Installation Services requirements as defined in University of California Request for Proposal “#001225-May2019 - University of California Systemwide Flooring”.
2. Term of SOW
This SOW will begin on April 15th, 2020 (“Effective Date”) and continue through April 14th, 2025. This SOW may not be renewed or otherwise amended except through a Change Order pursuant to the Change Management section below.
3. Key Tasks and Activities, Deliverables and Completion Timeframe Supplier Obligations
Task Activities Deliverables
Completion
Date or
Timeframe
1 Flooring Products &
Services
Provide flooring products
services as needed either
directly or through a flooring
dealer.
Flooring Products,
Installation
Services, Recycling
& Reclamation of
Old Floor Covering
As requested
2 Quarterly KPI Reports Provide Quarterly reporting on
product recycling and small
business utilization as outlined
in Attachment C.
Quarterly KPI
Reports
30 days
following the
end of the
quarter
3 Monthly Purchase
Reports
Provide Monthly purchase
reports as defined in
Attachment C.
Monthly Sales
Reports
15 days
following the
last day of the
month
4. UC Obligations
Not Applicable
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F UCOP Agreement #2020002144 Page 2 of 5
5. Place(s) of Performance
Supplier agrees to make available products and services to any UC location upon the terms, conditions, and pricing set forth in this agreement. Additionally, products and services will be made available nationally through OMNIA Partners member agencies.
6. Key Personnel
Supplier’s Account Manager is listed below , is subject to UC approval, and has overall responsibility for managing the UC/Supplier relationship:
Name Don Chupik, VP of Government & Education
Phone 714.944.7500
Email [email protected]
Address 616 E Walnut Ave
Dalton, GA 30722-2128
Supplier’s Account Management Team is:
Name Kelly Sherrill, Sr. Contract Specialist
Phone 706.879.3567
Email [email protected]
Address 230 Douthit Ferry Road
Cartersville, GA 30120
Name Rosio Hernandez, (Order Entry and Project) Account Manager Phone 770.276.7511
Email [email protected]
Address 770 Joe Frank Harris Pkwy
Cartersville, GA 30120
UC’S Project Manager, responsible for acceptance/rejection of project results/deliverables, is:
Name Reynaldo Cano-Boza
Phone 510.987.9893
Email [email protected]
Address 7835 Trade Street, Suite 100
San Diego, CA 92121
7. Reporting Requirements
Quarterly and Monthly Reports as described in Attachment C, including:
Quarterly – Recycling & Reclamation
Quarterly – Small Business Utilization
Monthly – Purchases
Supplier agrees to register and participate in an assessment of their sustainability practices and procedures through EcoVadis Corporate Social Responsibility (CSR) monitoring platform within 60 days of agreement signature.
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
UCOP Agreement #2020002144 Page 3 of 5
Supplier agrees to provide other reports as reasonably requested by UC during the Term of the Agreement and any extension(s) to the Term at no additional cost to UC.
8. Service Level Agreement
During the Term of the Agreement, and any extension(s) of the Term, Supp lier will meet Service Levels defined under section 5 requirements as defined in University of California Request for Proposal “#001225- May2019 - University of California Systemwide Flooring”.
The minimum service standards set forth above recognize that occasional errors are likely; however, Supplier further agrees to use its best efforts to achieve 100% of service levels. Should the service levels fall below the minimum standards and Supplier does not take corrective action within fourteen (14) days following UC written notification, UC reserves the right to terminate the Agreement immediately.
9. Program Requirements
Order Packaging and Labeling. Supplier agrees that each UC order will be individually wrapped and labeled with the following information:
Purchase Order number;
Product description, quantity and catalog number of the product ordered and an open 30-character field for internal identification e.g., UC storehouse catalog numbers and/or internal customer order numbers; and
Other information, as may be requested by ordering UC Location.
Packaging slips will be attached to the outside of the package such that it can be inspected by UC at the requesting department and/or receiving dock.
Receiving Locations. Supplier agrees to provide desktop and dock delivery to all UC current and future authorized personnel delivery points, as requested by UC.
Standard Delivery Requirements. Supplier will deliver Monday through Friday, excluding UC - and Supplier- observed holidays. Supplier provide UC with a schedule on or before September 1 of the following calendar year showing holidays and other planned shutdowns (such as the annual inven tory) that would impact Supplier’s ability to deliver the Goods and/or Services. Supplier agrees to deliver all UC orders received by 3:30pm Pacific Time the next business day as follows:
Campus direct (desktop delivery) - by 3:30 pm Pacific Time Storehouse (drop ship delivery) - by 10:00 am Pacific Time
Delivery Delays. Supplier will report any delivery delay whatsoever to the ordering Location, as well as its cause, within twenty-four (24) hours after Supplier is able to reasonably determine there will be a delay; the report will be provided to UC by telephone, e -mail, or facsimile. Supplier will keep UC fully informed and will take all reasonable action in eliminating the cause of delay.
Returns. Supplier agrees to accept standard Goods returned by UC if in resalable condition and if made within thirty (30) days of original shipment. Returns of standard goods may result in a 15% restocking fee, as well as any applicable shipping charges. Returns will not be allowed on custom or made to order styles.
Supplier agrees to pay freight on any returns resul ting from an error in shipment including, but not limited to, incorrect style, quantity, location, etc.
Credit. Requests for credit can be transmitted by the ordering UC personnel via the established order management system (telephone, fax, paper return form, and web-based). Chargebacks and credit memos will be issued to UC ordering departments in the current month’s billing period. Return items will be DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F UCOP Agreement #2020002144 Page 4 of 5
credited at cost, less any applicable fees . If Goods were purchased via UC purchasing card, credit must be issued to the same purchasing card.
Out of Stock Items. If there is an out of stock situation of any ordered inventoried item(s), the out of stock item will be added to the back order file and will be delivered to UC when the item is in stock wi thout a further order being submitted.
Surveys. Supplier will, at UC’s request, conduct customer surveys of UC orders through questionnaires. The content of these surveys will be approved by UC. UC will be responsible for the tabulation of these surveys.
10. Partnership Opportunities
Upon mutual terms, Supplier and UC Campuses may engage in partnership opportunities that align the teaching, research and service mission of the University with strategic supplier relationships. These opportunities allow the Supplier to more directly impact student, academic, research and alumni stakeholders throughout the University. Opportunities include, but are not limited to:
Student Internship & Career Development Opportunities Projects & Research focused on advancing sustainability of flooring products & services Guest lecture opportunities for design, engineering, sustainability, and business disciplines Sponsorship of Intercollegiate Athletics, Alumni, Associated Student Groups, etc.
11. Changes to the Services
UC may desire to change the Goods and/or Services following execution of an SOW. If so, UC will submit a written Amendment to Supplier describing the changes in appropriate detail . If an Amendment does not require Supplier to incur any additional material costs or expenses, then Supplier will make, or take material steps towards making, the modification within ten (10) business days of Supplier’s receipt of UC’s Amendment. If an Amendment does require that Supplier incur additional material costs or expenses, then Supplier in good faith will provide UC with a written, high level, non -binding assessment of the costs and expenses and the time required to perform the modifications required by the Amendment, within ten (10) business days of Supplier’s receipt of UC’s Amendment. UC will notify Supplier in writing within ten (10) business days after receipt of Supplier’s response to the Amendment as to whether UC wishes Supplier to implement the Amendment based on the response. UC will compensate Supplier for implementation of an Amendment in accordance with the terms and conditions of the relevan t Amendment and Supplier’s response to the Amendment, if any. Supplier’s implementation of a n Amendment will not delay the performance of Services and/or the delivery of deliverables not reasonably affected by a n Amendment.
12. No Mandatory Use
Because there is no mandatory use policy at UC, nothing in this Statement of Work will be construed to prevent UC from entering into similar agreements with any third parties including, without limitation, suppliers that may be in competition with Supplier.
This Statement of Work is signed below by the parties’ duly authorized representatives.
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F UCOP Agreement #2020002144 Page 5 of 5
THE REGENTS OF THE Shaw Industries, Inc.
UNIVERSITY OF CALIFORNIA
________________________________ ____________________________________ (Signature) (Signature)
________________________________ ____________________________________ (Printed Name, Title) (Printed Name, Title)
________________________________ ____________________________________ (Date) (Date)
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F Jim Kirkpatrick Treasurer
4/22/2020
Executive Director
4/23/2020
Justin Sullivan
UCOP-OMNIA Pricing
Style Number Style Name Type UOM List Discount
Off List Price Chemicals of Concern EPD
Broadloom
60283 AMBITION II CLASSICBAC® BROADLOOM SY 6.47$ 36% 4.15$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A240 AMBITION III 20 CLASSICBAC® BROADLOOM SY 8.91$ 37% 5.63$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A241 AMBITION III 26 CLASSICBAC® BROADLOOM SY 10.53$ 47% 5.63$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60114 HOMESTEAD CLASSICBAC® BROADLOOM SY 11.74$ 48% 6.09$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60117 UPSCALE CLASSICBAC® BROADLOOM SY 13.96$ 50% 7.04$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60127 HARBOR CLASSICBAC® BROADLOOM SY 15.06$ 49% 7.65$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A252 AMEND BROADLOOM SY 15.30$ 49% 7.73$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A253 ACCORD BROADLOOM SY 15.30$ 49% 7.73$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A068 POTENTIAL III 26 CLASSICBAC® BROADLOOM SY 15.41$ 49% 7.80$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60773 TOWN RESORT CLASSICBAC® BROADLOOM SY 16.32$ 50% 8.18$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A254 MEMOIRS BROADLOOM SY 16.92$ 51% 8.24$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A069 POTENTIAL III 28 CLASSICBAC® BROADLOOM SY 15.75$ 47% 8.39$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A188 ESSENTIAL CLASSICBAC® BROADLOOM SY 16.45$ 49% 8.46$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A189 PRIME CLASSICBAC® BROADLOOM SY 16.45$ 49% 8.46$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60587 POTENTIAL III 26 UNITARY BROADLOOM SY 16.41$ 48% 8.51$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60602 MOMENTUM IV UNITARY BROADLOOM SY 16.15$ 46% 8.67$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A037 TERRA CLASSICBAC® BROADLOOM SY 18.22$ 52% 8.67$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A038 FOSSIL CLASSICBAC® BROADLOOM SY 18.22$ 52% 8.67$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60588 POTENTIAL III 28 UNITARY BROADLOOM SY 16.83$ 47% 8.95$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60563 ASSOCIATE ULTRALOC® PATTERN BROADLOOM SY 18.69$ 52% 9.00$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A255 SCENERY BROADLOOM SY 19.08$ 51% 9.27$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A165 MELD CLASSICBAC® BROADLOOM SY 19.62$ 53% 9.31$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A025 PETO II CLASSICBAC® BROADLOOM SY 19.42$ 50% 9.71$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A032 DESIGN SERIES V 30 CLASSICBAC® BROADLOOM SY 18.64$ 47% 9.79$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 5A174 FLICKER CLASSICBAC® BROADLOOM SY 19.29$ 49% 9.89$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A175 FLARE CLASSICBAC® BROADLOOM SY 19.56$ 49% 9.89$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A205 SWITCH CLASSICBAC® BROADLOOM SY 20.81$ 52% 9.93$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A164 ECLECTIC CLASSICBAC® BROADLOOM SY 19.44$ 48% 10.07$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A203 TRANSFER CLASSICBAC® BROADLOOM SY 20.81$ 52% 10.08$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A186 CONTOUR CLASSICBAC® BROADLOOM SY 20.25$ 50% 10.12$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A187 OUTLINE CLASSICBAC® BROADLOOM SY 20.25$ 50% 10.12$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A216 STYLUS CLASSICBAC® BROADLOOM SY 19.57$ 48% 10.19$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
50911 SPACE CLASSICBAC® BROADLOOM SY 20.36$ 50% 10.20$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A204 MODIFY CLASSICBAC® BROADLOOM SY 20.81$ 51% 10.23$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A065 DIVIDE CLASSICBAC® BROADLOOM SY 20.12$ 49% 10.26$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A066 EQUAL CLASSICBAC® BROADLOOM SY 20.10$ 49% 10.26$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A067 EDIT CLASSICBAC® BROADLOOM SY 20.11$ 49% 10.26$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A233 SUMMIT CLASSICBAC® BROADLOOM SY 20.33$ 50% 10.26$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A234 GROVE CLASSICBAC® BROADLOOM SY 20.33$ 50% 10.26$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A235 BIRCH CLASSICBAC® BROADLOOM SY 20.33$ 50% 10.26$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A247 STAY ULTRALOC® BROADLOOM SY 21.78$ 53% 10.26$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A248 REMINISCE ULTRALOC® BROADLOOM SY 22.32$ 54% 10.26$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A256 REIMAGINE BROADLOOM SY 21.15$ 51% 10.30$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A151 TINT CLASSICBAC® BROADLOOM SY 19.55$ 47% 10.41$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A152 TONE CLASSICBAC® BROADLOOM SY 18.63$ 44% 10.41$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60774 IMAGERY CLASSICBAC® BROADLOOM SY 19.08$ 45% 10.54$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60775 SENTIMENT CLASSICBAC® BROADLOOM SY 19.86$ 47% 10.54$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A215 SCRIBE CLASSICBAC® BROADLOOM SY 19.57$ 46% 10.56$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60589 INTERPLAY ULTRALOC® PATTERN BROADLOOM SY 20.98$ 49% 10.63$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
50912 CULTURE CLASSICBAC® BROADLOOM SY 20.34$ 47% 10.88$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
50913 EVOLUTION CLASSICBAC® BROADLOOM SY 20.47$ 46% 11.07$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60514 SCHOLAR II UNITARY BROADLOOM SY 19.62$ 43% 11.17$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 60185 VILLA CLASSICBAC® BROADLOOM SY 26.14$ 57% 11.25$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A153 GRADIENT ULTRALOC® BROADLOOM SY 19.58$ 42% 11.32$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A257 STATEMENT BROADLOOM SY 23.31$ 51% 11.33$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A123 * TEXT CLASSICBAC® BROADLOOM SY 20.31$ 44% 11.43$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60730 PROSPER CLASSICBAC® BROADLOOM SY 24.15$ 52% 11.61$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60728 ACCOMLPISH CLASSICBAC® BROADLOOM SY 24.14$ 52% 11.63$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60497 * FIELD TRIP ULTRALOC® PATTERN BROADLOOM SY 23.54$ 50% 11.71$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A033 DESIGN SERIES V 36 CLASSICBAC® BROADLOOM SY 25.23$ 53% 11.95$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A124 * TEXT ULTRALOC® PATTERN BROADLOOM SY 23.36$ 48% 12.05$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60759 ASPIRE CLASSICBAC® BROADLOOM SY 26.63$ 51% 12.95$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60751 WHISPER WALLCOVERING SBR LATEX BROADLOOM SY 23.37$ 42% 13.62$ No 60665 * FIELD TRIP ECOWORX® PERFORMANCE
BROADLOOM
BROADLOOM SY 31.08$ 54% 14.23$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A183 LAYER ULTRALOC® PATTERN BROADLOOM SY 25.41$ 43% 14.36$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A184 DIMENSION ULTRALOC® PATTERN BROADLOOM SY 25.41$ 43% 14.36$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60734 * CHARISMA ECOWORX® PERFORMANCE
BROADLOOM
BROADLOOM SY 32.12$ 55% 14.42$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
50875 * MOVEMENT ULTRALOC® PATTERN BROADLOOM SY 34.50$ 58% 14.44$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A176 AMPLIFY ULTRALOC® PATTERN BROADLOOM SY 28.65$ 49% 14.53$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60726 PROSPER ECOWORX® PERFORMANCE
BROADLOOM
BROADLOOM SY 31.43$ 53% 14.63$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A213 CONTE' ULTRALOC® PATTERN BROADLOOM SY 27.02$ 45% 14.85$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A214 ERASE ULTRALOC® PATTERN BROADLOOM SY 27.02$ 44% 15.00$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 60727 ACCOMLPISH ECOWORX® PERFORMANCE
BROADLOOM
BROADLOOM SY 31.42$ 52% 15.06$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A177 ILLUMINATE ULTRALOC® PATTERN BROADLOOM SY 28.65$ 46% 15.55$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A017 * SHIMMER ULTRALOC® PATTERN BROADLOOM SY 35.04$ 56% 15.58$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A236 BOTAN ULTRALOC® PATTERN BROADLOOM SY 30.45$ 49% 15.65$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60772 FAÇADE ECOWORX® PERFORMANCE
BROADLOOM
BROADLOOM SY 26.45$ 39% 16.02$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A238 KUSA ULTRALOC® PATTERN BROADLOOM SY 29.40$ 45% 16.09$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60735 HIGHLIGHT ECOWORX® PERFORMANCE
BROADLOOM
BROADLOOM SY 32.70$ 50% 16.29$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60758 ASPIRE ECOWORX® PERFORMANCE BROADLOOM BROADLOOM SY 33.32$ 51% 16.37$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A237 HANA ULTRALOC® PATTERN BROADLOOM SY 30.65$ 46% 16.42$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60736 PROFILE ECOWORX® PERFORMANCE
BROADLOOM
BROADLOOM SY 34.86$ 49% 17.72$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A141 * NAVIGATE ULTRALOC® PATTERN BROADLOOM SY 32.83$ 46% 17.80$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60766 COLLAGE ECOWORX® PERFORMANCE
BROADLOOM
BROADLOOM SY 34.41$ 46% 18.70$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5A242 ESCAPE ULTRALOC® BROADLOOM SY 31.98$ 41% 18.71$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60755 BRIDGE ECOWORX® PERFORMANCE BROADLOOM BROADLOOM SY 36.15$ 47% 19.14$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60754 * ESSENCE ULTRALOC® PATTERN BROADLOOM SY 40.38$ 52% 19.24$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
60737 CADENCE ECOWORX® PERFORMANCE
BROADLOOM
BROADLOOM SY 38.67$ 47% 20.51$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F Walk-off
5T033 ENTREE ECOWORX® TILE TILE SY 55.19$ 43% 31.42$ Trace amounts of Fly Ash from Recycled Content
No
59411 BON JOUR ECOWORX® TILE TILE SY 55.29$ 57% 23.57$ Trace amounts of Fly Ash from Recycled Content
No
5T032 BON JOUR II ECOWORX® TILE TILE SY 55.19$ 46% 29.93$ Trace amounts of Fly Ash from Recycled Content
No
60746 BON JOUR II PERFORMANCE RUBBER BACKING BROADLOOM SY 43.48$ 43% 24.66$ No Tile
5T208 INTENT ECOWORX® TILE TILE SY 23.31$ 50% 11.56$ Mineral based non-halogenated flame retardant for regulatory requirements
No
5T209 PURPOSE ECOWORX® TILE - STRUTUM TILE SY 23.31$ 50% 11.56$ Mineral based non-halogenated flame retardant for regulatory requirements
No
5T210 SITUATION ECOWORX® TILE TILE SY 23.31$ 50% 11.56$ Mineral based non-halogenated flame retardant for regulatory requirements
No
5T294 ARRANGE TILE TILE SY 24.93$ 51% 12.11$ Mineral based non-halogenated flame retardant for regulatory requirements
No
5T295 ARRAY TILE TILE SY 24.93$ 51% 12.11$ Mineral based non-halogenated flame retardant for regulatory requirements
No
5T296 OFFSET TILE TILE SY 24.93$ 51% 12.11$ Mineral based non-halogenated flame retardant for regulatory requirements
No
5T297 STRUCTURE TILE TILE SY 24.93$ 51% 12.11$ Mineral based non-halogenated flame retardant for regulatory requirements
No
5T123 PRIMARY ECOWORX® TILE TILE SY 27.81$ 50% 14.04$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T206 POURED ECOWORX® TILE TILE SY 29.07$ 50% 14.41$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T207 STACKED ECOWORX® TILE TILE SY 29.07$ 50% 14.65$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T121 BASIC ECOWORX® TILE TILE SY 27.81$ 46% 15.00$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59579 CATALYST ECOWORX® TILE TILE SY 32.01$ 53% 15.04$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59580 HYBRID ECOWORX® TILE TILE SY 32.01$ 53% 15.16$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T125 SURROUND ECOWORX® TILE TILE SY 30.27$ 50% 15.24$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T070 SHAPE ECOWORX® TILE TILE SY 32.54$ 53% 15.35$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T124 CENTRIC ECOWORX® TILE TILE SY 30.27$ 49% 15.45$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 5T009 VAST ECOWORX® TILE TILE SY 36.08$ 57% 15.47$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T172 SEA ECOWORX® TILE TILE SY 30.82$ 49% 15.62$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T019 TEMPT ECOWORX® TILE TILE SY 33.97$ 54% 15.73$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T069 REVERSE ECOWORX® TILE TILE SY 32.54$ 51% 15.80$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59563 TRANSPARENT ECOWORX® TILE TILE SY 29.73$ 47% 15.86$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59576 DISPERSE ECOWORX® TILE TILE SY 34.19$ 53% 15.97$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59502 MOMENTUM IV ECOWORX® TILE TILE SY 32.48$ 51% 16.02$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T078 REALM ECOWORX® TILE TILE SY 33.27$ 52% 16.04$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59224 STRAIGHTFORWARD ECOWORX® TILE TILE SY 37.95$ 58% 16.06$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59575 DIFFUSE ECOWORX® TILE TILE SY 33.97$ 53% 16.06$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59564 CLEAR ECOWORX® TILE TILE SY 29.72$ 46% 16.08$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T173 SEA EDGE ECOWORX® TILE TILE SY 30.82$ 48% 16.08$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T010 INFINITE ECOWORX® TILE TILE SY 36.08$ 55% 16.13$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T079 FIELD ECOWORX® TILE TILE SY 34.18$ 53% 16.15$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T261
BELONG ECOWORX® TILE TILE SY 32.13$ 50%
16.17$
Trace amounts of Fly Ash from Recycled
Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59562 GLAZE ECOWORX® TILE TILE SY 29.74$ 46% 16.19$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 59327 ALLURE ECOWORX® TILE TILE SY 30.73$ 47% 16.21$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59328 SHINE ECOWORX® TILE TILE SY 30.73$ 47% 16.24$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T185 DIFFUSE 9X36 ECOWORX® TILE TILE SY 33.09$ 51% 16.24$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T174 SKY ECOWORX® TILE TILE SY 30.82$ 47% 16.26$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T265 DREAM ECOWORX® TILE TILE SY 31.95$ 49% 16.34$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T263 MEMORY ECOWORX® TILE TILE SY 32.22$ 49% 16.46$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59329 GLIMMER ECOWORX® TILE TILE SY 30.73$ 46% 16.47$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T018 TANGLE ECOWORX® TILE TILE SY 33.97$ 51% 16.48$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T040 EMBARK ECOWORX® TILE TILE SY 32.76$ 50% 16.48$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T080 SCAPE ECOWORX® TILE TILE SY 33.18$ 50% 16.48$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T184 DISPERSE 9X36 ECOWORX® TILE TILE SY 33.09$ 49% 16.72$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T039 * WANDER ECOWORX® TILE TILE SY 32.76$ 49% 16.76$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T175 CITY CENTRAL ECOWORX® TILE TILE SY 33.18$ 49% 16.76$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T156 TINGE ECOWORX® TILE TILE SY 31.72$ 47% 16.79$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T157 UNDERTONE ECOWORX® TILE TILE SY 31.72$ 47% 16.80$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T071 DIRECTION ECOWORX® TILE TILE SY 32.54$ 47% 17.17$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 59369 PETO II 20 ECOWORX® TILE TILE SY 36.99$ 53% 17.51$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T176 CENTRAL LINE ECOWORX® TILE TILE SY 33.18$ 47% 17.53$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59113 BYLINE ECOWORX® TILE TILE SY 33.57$ 48% 17.55$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T232 CHALET 9" X 36" ECOWORX® TILE TILE SY 36.45$ 52% 17.67$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T233 DIFFUSE 24X24 ECOLOGIX TILE SY 34.63$ 49% 17.80$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59558 INTRIGUE ECOWORX® TILE TILE SY 35.11$ 49% 17.84$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59554 CAPTIVATE ECOWORX® TILE TILE SY 35.12$ 49% 17.91$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59106 LINAGE ECOWORX® TILE TILE SY 33.64$ 47% 17.93$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T183 SCULPT LOOP ECOWORX® TILE TILE SY 42.17$ 57% 17.95$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T186 THINK ECOWORX® TILE TILE SY 34.81$ 48% 17.98$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T081 COLOR FRAME ECOWORX® TILE TILE SY 41.56$ 56% 18.11$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T187 ENGAGE ECOWORX® TILE TILE SY 34.81$ 48% 18.16$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T188 IMPACT ECOWORX® TILE TILE SY 37.16$ 50% 18.47$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59105 LINK ECOWORX® TILE TILE SY 33.64$ 45% 18.61$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T036 * VAPOR ECOWORX® TILE TILE SY 44.01$ 57% 19.06$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T105 ROTATE ECOWORX® TILE TILE SY 38.39$ 50% 19.08$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 59387 REPARTEE ECOWORX® TILE TILE SY 42.35$ 55% 19.11$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T234 DIFFUSE 24X24 ECOLOGIX ES TILE SY 36.60$ 47% 19.42$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T198 BASALT II ECOWORX® TILE TILE SY 41.60$ 53%
19.55$
Trace amounts of Fly Ash from Recycled
Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59534 GRADIENT ECOWORX® TILE TILE SY 37.66$ 48% 19.62$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T112 COLOR FORM ECOWORX® TILE TILE SY 40.38$ 51% 19.68$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T199 FAULT LINES II ECOWORX® TILE TILE SY 41.60$ 53% 19.68$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T200 GRAVEL II ECOWORX® TILE
3.25%
TILE SY 41.60$ 53% 19.68$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T201 PAVERS II ECOWORX® TILE TILE SY 41.60$ 53% 19.69$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T038 * FRINGE ECOWORX® TILE TILE SY 44.01$ 55% 19.90$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59371 PETO II 26 ECOWORX® TILE TILE SY 46.65$ 57% 19.94$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T110 VALUE ECOWORX® TILE TILE SY 44.77$ 55% 20.18$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T064 AUGMENT ECOWORX® TILE TILE SY 40.88$ 51% 20.19$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T116 STIPPLE ECOWORX® TILE TILE SY 47.80$ 58% 20.19$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T103 COPY TILE TILE SY 38.39$ 47% 20.31$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T127 DISTORT ECOWORX® TILE TILE SY 44.09$ 54% 20.40$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T104 CONSTRUCT ECOWORX® TILE TILE SY 38.39$ 47% 20.49$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 5T107 ACHROMATIC ECOWORX® TILE TILE SY 44.77$ 54% 20.54$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T109 SATURATE ECOWORX® TILE TILE SY 44.77$ 54% 20.56$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59463 PRISMA ECOWORX® TILE TILE SY 43.50$ 52% 20.77$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T065 HYPE ECOWORX® TILE TILE SY 40.88$ 49% 20.77$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59342 * CONNECT ECOWORX® TILE TILE SY 40.47$ 48% 20.85$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T126 ANALOG ECOWORX® TILE TILE SY 44.09$ 52% 21.01$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T037 HAZE ECOWORX® TILE TILE SY 44.01$ 52% 21.12$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T004 APPLIED ECOWORX® TILE TILE SY 43.40$ 51% 21.15$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T002 VISIBLE ECOWORX® TILE TILE SY 43.40$ 51% 21.23$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T108 DUOTONE ECOWORX® TILE
2.35%
TILE SY 44.77$ 52% 21.28$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T240 SHELTER ECOWORX® TILE TILE SY 44.04$ 51% 21.41$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T003 ABSORBED ECOWORX® TILE TILE SY 43.40$ 51% 21.46$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T051 * STILL ECOWORX® TILE TILE SY 47.59$ 55% 21.56$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T001 VIBRANT ECOWORX® TILE TILE SY 43.40$ 50% 21.57$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T202 ADVANCE ECOWORX® TILE TILE SY 45.36$ 52% 21.58$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59455 * FOCUS ECOWORX® TILE TILE SY 42.37$ 49% 21.59$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 59466 MIRROR IMAGE ECOWORX® TILE TILE SY 44.77$ 52% 21.61$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59550 * SITE LINES ECOWORX® TILE TILE SY 44.45$ 51% 21.64$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T114 LINEWEIGHT ECOWORX® TILE TILE SY 47.80$ 55% 21.64$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T203 DASH ECOWORX® TILE TILE SY 45.36$ 52% 21.69$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T143 EXPLORE ECOWORX® TILE TILE SY 48.47$ 55% 21.70$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T238 NEST ECOWORX® TILE TILE SY 44.04$ 51% 21.70$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T128 GLITCH ECOWORX® TILE
2.35%
TILE SY 44.09$ 51% 21.72$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T205 TURN ECOWORX® TILE TILE SY 45.36$ 52% 21.72$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T267 SUPPORT TILE TILE SY 39.33$ 45% 21.75$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T268 ESTABLISH TILE TILE SY 39.33$ 45% 21.75$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T269 CONVENE TILE TILE SY 39.33$ 45% 21.75$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T194 KUSA ECOWORX® TILE TILE SY 46.91$ 54% 21.77$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T130 MANIPULATE ECOWORX® TILE TILE SY 44.09$ 51% 21.81$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T007 SCULPT ECOWORX® TILE TILE SY 44.70$ 51% 21.85$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59343 EMOTION ECOWORX TILE TILE SY 42.14$ 48% 22.05$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T239 DWELLING ECOWORX® TILE TILE SY 44.04$ 49% 22.29$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 5T204 TRACK ECOWORX® TILE TILE SY 45.36$ 51% 22.40$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59358 * COLOR PLAY ECOWORX® TILE TILE SY 48.06$ 53% 22.41$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T193 HANA ECOWORX® TILE TILE SY 48.76$ 54% 22.67$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T006 ALIGN ECOWORX® TILE TILE SY 44.70$ 49% 22.73$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T005 TRACE ECOWORX® TILE TILE SY 44.70$ 49% 22.74$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59359 * KINETIC ECOWORX® TILE TILE SY 47.92$ 52% 22.78$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59529 BRILLIANCE ECOWORX® TILE TILE SY 41.25$ 45% 22.88$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59530 STRIKING ECOWORX® TILE TILE SY 43.17$ 47% 23.04$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T059 * EXPAND ECOWORX® TILE TILE SY 49.21$ 53% 23.09$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T113 FINE POINT ECOWORX® TILE TILE SY 47.80$ 51% 23.24$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T151 * EXPOSE ECOWORX® TILE TILE SY 46.53$ 50% 23.37$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T085 INTERACT ECOWORX® TILE TILE SY 48.28$ 52% 23.38$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T083 PAUSE ECOWORX® TILE TILE SY 47.11$ 50% 23.44$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T049 * IGNITE ECOWORX® TILE TILE SY 47.59$ 51% 23.53$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59583 CHROMA ECOWORX® TILE TILE SY 46.44$ 49% 23.59$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T192 BOTAN ECOWORX® TILE TILE SY 48.76$ 52% 23.61$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 5T241 CURVE ECOWORX® TILE TILE SY 40.05$ 41% 23.70$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T242 DIAGONAL ECOWORX® TILE TILE SY 40.05$ 41% 23.70$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T243 POINT ECOWORX® TILE TILE SY 40.05$ 41% 23.70$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T017 * QUARTZ ECOWORX® TILE TILE SY 52.78$ 55% 23.76$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
I0204 COLOR CHOICE MODULAR TILE SY 51.89$ 54% 23.77$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T086 VANTAGE ECOWORX® TILE TILE SY 47.11$ 49% 23.82$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T084 STEP ECOWORX® TILE TILE SY 47.11$ 49% 23.85$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T244 SQUARE ECOWORX® TILE TILE SY 40.05$ 40% 23.94$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T216 SEEK ECOWORX® TILE TILE SY 51.79$ 54% 23.96$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T152 * RELIEF ECOWORX® TILE TILE SY 46.53$ 48% 23.97$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T014 * MICA ECOWORX® TILE TILE SY 52.78$ 55% 23.99$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59572 * BLOCK PRINT ECOWORX® TILE TILE SY 46.70$ 48% 24.20$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T150 UNCOVER ECOWORX® TILE TILE SY 46.53$ 48% 24.20$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59573 EMBELLISH ECOWORX® TILE TILE SY 42.33$ 43% 24.22$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59591 SKETCH ECOWORX® TILE TILE SY 48.86$ 50% 24.23$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59368 TRU COLOURS ECOWORX® TILE TILE SY 54.02$ 55% 24.26$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 59592 IMPRINT ECOWORX® TILE TILE SY 48.72$ 50% 24.39$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T144 LINGER ECOWORX® TILE TILE SY 47.21$ 48% 24.40$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59537 * CITY GRID ECOWORX® TILE TILE SY 48.03$ 49% 24.41$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T016 * JASPER ECOWORX® TILE TILE SY 52.78$ 54% 24.41$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59167 * MERGE ECOWORX® TILE TILE SY 48.64$ 50% 24.42$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T141 RENEW ECOWORX® TILE TILE SY 48.47$ 50% 24.47$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T035 PORTAL ECOWORX® TILE TILE SY 54.43$ 55% 24.57$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59584 SPECTRUM ECOWORX® TILE TILE SY 46.24$ 47% 24.59$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59597 FADE ECOWORX® TILE TILE SY 52.77$ 53% 24.90$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59596 BLUR ECOWORX® TILE TILE SY 52.77$ 52% 25.07$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59525 PRAIRIE ECOWORX® TILE TILE SY 47.67$ 47% 25.26$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59598 OVERLAY ECOWORX® TILE TILE SY 52.77$ 52% 25.28$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T091 REST ECOWORX® TILE TILE SY 46.53$ 45% 25.44$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59361 RADIANCE ECOWORX® TILE TILE SY 57.80$ 56% 25.72$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59114 VERTICAL EDGE ECOWORX® TILE TILE SY 54.94$ 53% 25.75$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T031 WELCOME II ECOWORX® TILE TILE SY 55.19$ 53% 26.15$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 59363 RICHE ECOWORX® TILE TILE SY 48.32$ 45% 26.53$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59360 GLITZ ECOWORX® TILE TILE SY 57.82$ 54% 26.56$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T058 ANGLE ECOWORX® TILE TILE SY 59.48$ 55% 26.72$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59362 LUMINOSITY ECOWORX® TILE TILE SY 57.96$ 54% 26.94$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T257 IMPRESSION I ECOWORX® TILE TILE SY 46.53$ 42% 26.94$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T258 IMPRESSION II ECOWORX® TILE TILE SY 46.53$ 42% 26.94$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T259 IMPRESSION III ECOWORX® TILE TILE SY 46.53$ 42% 26.94$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T034 PATH ECOWORX® TILE TILE SY 54.43$ 50% 27.42$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
59115 * HORIZONTAL EDGE ECOWORX® TILE TILE SY 54.94$ 50% 27.47$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T161 COLOR SHIFT HEXAGON ECOWORX® TILE TILE SY 57.33$ 49% 29.42$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T041 DYE LAB ECOWORX® TILE TILE SY 63.57$ 52% 30.26$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T159 BASE HEXAGON ECOWORX® TILE TILE SY 57.33$ 47% 30.26$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T160 CONTACT HEXAGON ECOWORX® TILE TILE SY 57.33$ 46% 30.75$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T054 PLANE HEXAGON ECOWORX® TILE TILE SY 64.14$ 52% 30.87$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T057 BEVEL HEXAGON ECOWORX® TILE TILE SY 74.95$ 54% 34.82$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
5T096 CLOTH ECOWORX® TILE TILE SY 83.71$ 51% 41.31$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 5T260 IMPRESSION IV ECOWORX® TILE TILE SY 46.53$ 42% 2,604.00$ Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame
retardant for regulatory requirements
Yes, ISO14025 Product
Specific EPD
Resilient
0655V TERRAIN 8 MIL RESILIENT SF 2.20$ 59% 0.91$ PVC Content YES, ISO14025 Industry Average EPD
0656V BRUSH 8 MIL RESILIENT SF 2.20$ 59% 0.91$ PVC Content YES, ISO14025 Industry Average EPD
0565V BRUSH 12 MIL RESILIENT SF 3.30$ 65% 1.14$ PVC Content YES, ISO14025 Industry Average EPD
0566V PLASTER 12 MILL RESILIENT SF 3.30$ 65% 1.14$ PVC Content YES, ISO14025 Industry Average EPD
0567V LINE 12 MIL RESILIENT SF 3.30$ 65% 1.14$ PVC Content YES, ISO14025 Industry Average EPD
0453V TERRAIN II 12MIL RESILIENT SF 3.00$ 62% 1.15$ PVC Content YES, ISO14025 Industry Average EPD
0116V NATIVE ORIGINS RESILIENT SF 2.86$ 57% 1.24$ PVC Content YES, ISO14025 Industry Average EPD
0517V TERRAIN 12MIL RESILIENT SF 3.30$ 62% 1.25$ PVC Content YES, ISO14025 Industry Average EPD
0009V DECO ADVANTAGE STONE RESILIENT SF 2.83$ 54% 1.30$ PVC Content YES, ISO14025 Industry Average EPD
0553V PLASTER 20 MIL RESILIENT SF 5.50$ 69% 1.71$ PVC Content YES, ISO14025 Industry Average EPD
0454V TERRAIN II 20MIL RESILIENT SF 5.50$ 65% 1.94$ PVC Content YES, ISO14025 Industry Average EPD
0564V TERRAIN 20MIL RESILIENT SF 5.50$ 65% 1.95$ PVC Content YES, ISO14025 Industry Average EPD
0692V INTRICATE RESILIENT SF 5.00$ 61% 1.95$ PVC Content YES, ISO14025 Industry Average EPD
0552V BRUSH 20 MIL RESILIENT SF 5.50$ 63% 2.02$ PVC Content YES, ISO14025 Industry Average EPD
0554V LINE 20 MIL RESILIENT SF 5.50$ 63% 2.02$ PVC Content YES, ISO14025 Industry Average EPD
0502V GRAIN - DIRECT GLUE RESILIENT SF 4.00$ 49% 2.03$ PVC Content YES, ISO14025 Industry Average EPD
0514V INTERVAL RESILIENT SF 5.00$ 59% 2.03$ PVC Content YES, ISO14025 Industry Average EPD
0515V SURFACE RESILIENT SF 5.00$ 59% 2.03$ PVC Content YES, ISO14025 Industry Average EPD
0516V STRAND RESILIENT SF 5.00$ 59% 2.03$ PVC Content YES, ISO14025 Industry Average EPD
0188V UNCOMMON GROUND 6" RESILIENT SF 4.77$ 57% 2.07$ PVC Content YES, ISO14025 Industry Average EPD
0187V UNCOMMON GROUND 4" RESILIENT SF 4.77$ 56% 2.08$ PVC Content YES, ISO14025 Industry Average EPD
0993V JOY SQUARED RESILIENT SF 5.00$ 57% 2.16$ PVC Content YES, ISO14025 Industry Average EPD
0203V CRETE RESILIENT SF 4.64$ 52% 2.21$ PVC Content YES, ISO14025 Industry Average EPD
0215V JEOGORI RESILIENT SF 4.64$ 52% 2.21$ PVC Content YES, ISO14025 Industry Average EPD
0503V PIGMENT - DIRECT GLUE RESILIENT SF 4.00$ 45% 2.21$ PVC Content YES, ISO14025 Industry Average EPD
0892V TERRAIN II 30 MIL RESILIENT SF 5.10$ 56% 2.23$ PVC Content YES, ISO14025 Industry Average EPD
0618V EMERGE RESILIENT SF 5.00$ 52% 2.42$ PVC Content YES, ISO14025 Industry Average EPD
0601V UNVEIL RESILIENT SF 5.15$ 52% 2.49$ PVC Content YES, ISO14025 Industry Average EPD
0648V SOLITUDE RESILIENT SF 5.15$ 51% 2.53$ PVC Content YES, ISO14025 Industry Average EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 0922V CUT RESILIENT SF 5.00$ 49% 2.54$ PVC Content YES, ISO14025 Industry Average EPD
0364V GRAIN RESILIENT SF 6.24$ 58% 2.63$ PVC Content YES, ISO14025 Industry Average EPD
0945V SHEAR RESILIENT SF 5.00$ 45% 2.73$ PVC Content YES, ISO14025 Industry Average EPD
098UV COMPOSED RESILIENT SF 6.60$ 57% 2.85$ PVC Content YES, ISO14025 Industry Average EPD
0926V INLET RESILIENT SF 6.00$ 52% 2.87$ PVC Content YES, ISO14025 Industry Average EPD
0927V COVE RESILIENT SF 6.00$ 52% 2.87$ PVC Content YES, ISO14025 Industry Average EPD
094UV CONCRETE RESILIENT SF 6.60$ 57% 2.87$ PVC Content YES, ISO14025 Industry Average EPD
0365V PIGMENT RESILIENT SF 6.24$ 53% 2.93$ PVC Content YES, ISO14025 Industry Average EPD
0186V QUIET COVER RESILIENT SF 6.74$ 56% 2.98$ PVC Content YES, ISO14025 Industry Average EPD
0895V INNATE (BIO BASED) RESILIENT SF 9.00$ 52% 4.33$ None Yes, ISO14025 Product Specific EPD
0896V IN TANDEM PLANK (BIO BASED) RESILIENT SF 9.00$ 52% 4.33$ None Yes, ISO14025 Product Specific EPD
0733V RETHINK RESILIENT SF 8.49$ 49% 4.35$ PVC Content YES, ISO14025 Industry Average EPD
0709V SHIFT RESILIENT SF 8.57$ 49% 4.39$ PVC Content YES, ISO14025 Industry Average EPD
0710V TILT RESILIENT SF 8.57$ 48% 4.48$ PVC Content YES, ISO14025 Industry Average EPD
0551V LEVEL HEXAGON RESILIENT SF 8.40$ 46% 4.53$ PVC Content YES, ISO14025 Industry Average EPD
0718V ARTESIAN RESILIENT SY 12.24$ 51% 6.02$ PVC Content YES, ISO14025 Industry Average EPD
0002V NATURELIFE WOOD RESILIENT SY 48.80$ 53% 22.71$ PVC Content YES, ISO14025 Industry Average EPD
0873V VITALITY RESILIENT SY 44.29$ 47% 23.63$ PVC Content YES, ISO14025 Industry Average EPD
0797V REED RESILIENT SY 44.29$ 45% 24.47$ PVC Content YES, ISO14025 Industry Average EPD
0798V ROJI RESILIENT SY 44.29$ 45% 24.47$ PVC Content YES, ISO14025 Industry Average EPD
0513V CHANGE RESILIENT SY 48.41$ 49% 24.50$ PVC Content YES, ISO14025 Industry Average EPD
0796V TATAMI RESILIENT SY 44.29$ 44% 24.68$ PVC Content YES, ISO14025 Industry Average EPD
0301V BASSTONES RESILIENT SY 51.50$ 52% 24.71$ PVC Content YES, ISO14025 Industry Average EPD
0512V CONSTANT RESILIENT SY 48.41$ 48% 25.23$ PVC Content YES, ISO14025 Industry Average EPD
0897V IN TANDEM SHEET (BIO BASED) RESILIENT SY 72.00$ 52% 34.64$ None Yes, ISO14025 Product Specific EPD
302VS COLLECTIVE TIME WELD ROD RESILIENT Roll 72.04$ 48% 37.24$ PVC Content No 353VS TERASU WELD ROD RESILIENT Roll 72.04$ 45% 39.40$ PVC Content No 087VS GROUNDWORKS RESILIENT Roll 75.00$ 45% 41.61$ None No 071VS HUSH II RESILIENT EA 319.88$ 43% 183.57$ None No Sports Flooring
0003V REXCOURT 4.5 (CONTAINER ONLY PRODUCT) RESILIENT SY 49.04$ 43% 28.04$ PVC Content No 0004V REXCOURT 6.5 RESILIENT SY 56.37$ 43% 32.08$ PVC Content No 0005V REXCOURT 8 (CONTAINER ONLY PRODUCT) RESILIENT SY 70.14$ 45% 38.89$ PVC Content No Adhesives
016VS COPPER RESILIENT Kit 0.74$ 20% 0.59$ None No DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F H8300 BROADLOOM MOISTURE IMPERVIOUS SEAM
SEALER
BROADLOOM EA 8.08$ 12% 7.14$ None No CATGA SHAW TONGUE AND GROOVE ADHESIVE HS EA 13.70$ 45% 7.53$ None No 165VS TRANSITION TAPE RESILIENT EA 16.00$ 44% 8.92$ None No H4000 BROADLOOM SEAM SEALERS BROADLOOM EA 13.04$ 23% 10.08$ None No 350VS QUARTER ROUND LVT RESILIENT EA 26.00$ 49% 13.33$ PVC Content No 015VS RESILIENT SEAM SEALER RESILIENT EA 23.53$ 27% 17.20$ None No 166VS COVE 1 GALLON ADHESIVE RESILIENT EA 42.00$ 49% 21.37$ None No H5001 5001 - CARPET TILE STANDARD ADHESIVE TILE Pail 26.73$ 17% 22.08$ None No 083VS SELITAC UNDERLAYMENT 100 SF/ROLL HS Roll 23.00$ 4% 22.10$ None No CAREM URETHANE ADHESIVE REMOVER HS Quart 47.90$ 46% 25.68$ None No CAA92 SHAW URETHANE HARDWOOD ADHESIVE
REMOVER WIPES
HS EA 49.27$ 46% 26.41$ None No
348VS MULTI PR RD LVT RESILIENT EA 52.00$ 46% 28.10$ PVC Content No 349VS T-MOLDING LVT RESILIENT EA 52.00$ 46% 28.18$ PVC Content No 01X46 QUARTER ROUND XRC - CONCRETE & COMPOSED RESILIENT EA 50.05$ 40% 29.86$ PVC Content No 066VS SHAW S150 SPRAY ADHESIVE RESILIENT EA 54.84$ 43% 31.43$ None No 067VS S150 - RESILIENT SPRAY (ROLLS) RESILIENT EA 54.84$ 43% 31.43$ None No SCUN1 TERRAIN OMNI-TRANSITION RESILIENT EA 50.05$ 32% 33.88$ PVC Content No SCUN2 TERRAIN II OMNI-TRANSITION RESILIENT EA 45.50$ 26% 33.88$ PVC Content No 01X20 BABY THRESHOLD XRC- CONCRETE & COMPOSED RESILIENT EA 50.05$ 32% 33.89$ PVC Content No H1200 MULTI‐PURPOSE ADHESIVE BROADLOOM Pail 47.10$ 28% 33.94$ None No 02X62 T-MOLD XRC - CONCRETE & COMPOSED RESILIENT EA 50.05$ 32% 34.19$ PVC Content No 02W26 T-MOLD CORETEC XL RESILIENT EA 50.05$ 32% 34.22$ PVC Content No H1000 BROADLOOM ADHESIVE BROADLOOM Pail 47.10$ 27% 34.22$ None No 01X70 REDUCER XRC - CONCRETE & COMPOSED RESILIENT EA 50.05$ 31% 34.42$ PVC Content No 02W13 FLUSH STAIR NOSE CORETEC EIRIS RESILIENT EA 50.05$ 31% 34.75$ PVC Content No 02W16 FLUSH STAIR NOSE CORETEC DEFINED RESILIENT EA 45.50$ 23% 34.84$ PVC Content No 02W04 FLUSH STAIR NOSE CORETEC XL RESILIENT EA 50.05$ 30% 34.97$ PVC Content No 02W12 FLUSH STAIR NOSE CORETEC LINEAR RESILIENT EA 45.50$ 23% 35.24$ PVC Content No 001VS BIOLIFE WELD ROD RESILIENT Roll 72.04$ 51% 35.40$ PVC Content No 01X95 STAIR NOSE XRC - CONCRETE & COMPOSED RESILIENT EA 59.68$ 40% 36.10$ PVC Content No 02W01 FLUSH STAIR NOSE CORETEC 500 RESILIENT EA 50.05$ 27% 36.60$ PVC Content No 236VS VITALITY WELD ROD RESILIENT Roll 72.04$ 48% 37.45$ PVC Content No 022VS CHORDINATES WELD ROD RESILIENT Roll 72.04$ 48% 37.77$ PVC Content No 002VS NATURELIFE WELD ROD RESILIENT Roll 72.04$ 48% 37.78$ PVC Content No SCQT1 TERRAIN QUARTER ROUND RESILIENT EA 50.05$ 23% 38.76$ PVC Content No SCQT2 TERRAIN II QUARTER ROUND RESILIENT EA 45.50$ 15% 38.76$ PVC Content No 02W06 FLUSH STAIR NOSE CORETEC 700 RESILIENT EA 50.05$ 22% 38.94$ PVC Content No 02W74 BABY THRESHOLD CAMARET HS EA 67.10$ 39% 40.66$ None No 347VS STAIRNOSE LVT RESILIENT EA 64.00$ 36% 40.74$ PVC Content No 02W17 FLUSH STAIR NOSE XRC - CONCRETE &
COMPOSED
RESILIENT EA 59.68$ 30% 41.97$ PVC Content No H1036 SUPERIOR GRADE MULTIPURPOSE ADHESIVE
CONTAINING FLORSEPT AATC174
BROADLOOM Pail 56.72$ 26% 42.19$ Added Antimicrobial No SCSN1 TERRAIN STAIRNOSE RESILIENT EA 59.68$ 28% 42.69$ PVC Content No SCSN2 TERRAIN II STAIRNOSE RESILIENT EA 54.25$ 21% 42.69$ PVC Content No 027VS SHAW 4100‐1G RESILIENT Pail 79.88$ 46% 43.32$ None No 028VS 4100 - RESILIENT 1 GALLON ADHESIVE(ROLLS) RESILIENT Pail 79.88$ 46% 43.32$ None No UV856 4100 - RESILIENT 1 GALLON ADHESIVE (UNITS) RESILIENT Pail 79.88$ 46% 43.32$ None No H3800 3800 - UNIVERSAL INDOOR/OUTDOOR ADHESIVE BROADLOOM Pail 58.33$ 23% 45.04$ None No L3800 3800 - UNIVERSAL INDOOR/OUTDOOR ADHESIVE
UNITS
BROADLOOM Pail 58.33$ 23% 45.04$ None No N3800 3800 - UNIVERSAL INDOOR/OUTDOOR ADHESIVE TILE Pail 58.33$ 23% 45.04$ None No H3600 ECO FLOR SEPT ADHESIVE BROADLOOM Pail 61.26$ 24% 46.26$ Added Antimicrobial No 096VS VSM VERSASHIELD 2" TAPE RESILIENT EA 71.25$ 33% 48.08$ None No DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 04W19 T-MOLD CAMARET HS EA 67.10$ 26% 49.69$ None No 03W38 REDUCER CAMARET HS EA 67.10$ 24% 50.81$ None No 03W07 QUARTER ROUND CAMARET HS EA 67.10$ 19% 54.21$ None No 031VS 9050 RESILIENT FLOOR PRIMER (ROLLS) RESILIENT Pail 95.69$ 43% 54.32$ None No 031VU 9050 - RESILIENT FLOOR PRIMER UNITS RESILIENT Pail 95.69$ 43% 54.32$ None No 032VS RESILIENT FLOOR PRIMER RESILIENT Pail 95.69$ 43% 54.32$ None No H9050 CARPET FLOOR PRIMER BROADLOOM Pail 95.69$ 43% 54.32$ None No H905U 9050 - FLOOR PRIMER UNITS BROADLOOM Pail 95.69$ 43% 54.32$ None No 097VS VSM MBX VERSASHIELD 2.5" TAPE (ROLLS) RESILIENT Roll 88.75$ 33% 59.54$ None No 098VS VSM VERSASHIELD 4" DS TAPE RESILIENT Roll 86.25$ 31% 59.54$ None No 146VS RESILIENT CARPET REDUCER RESILIENT Box 126.00$ 53% 59.71$ None No 021VS REXCOURT WELD ROD RESILIENT Roll 119.60$ 50% 59.91$ PVC Content No 00LDA LOKDOTS APPLICATOR TILE EA 82.10$ 23% 63.40$ None No 141VS COVE TUBE ADHESIVE RESILIENT Box 134.00$ 52% 63.85$ None No 03W73 STAIR CAP CAMARET HS EA 81.68$ 21% 64.25$ None No 270VS BIO-BASED WELD ROD RESILIENT Roll 135.00$ 49% 69.38$ None No N5000 5000 PRESSURE SENSITIVE TILE ADHESIVE TILE Pail 94.22$ 24% 71.81$ None No N5100 5100 ‐ PRESSURE SENSITIVE ADHESIVE TILE Pail 94.22$ 24% 71.81$ None No 148VS 4"W X 120'L WALL BASE ROLL RESILIENT Roll 160.80$ 53% 76.19$ PVC Content No N5036 5036 ‐ TILE ADHESIVE W/ ANTIMICROBIAL TILE Pail 99.68$ 23% 76.62$ Added Antimicrobial No 100CA MM800 RESILIENT 4 Gallon Pail 160.00$ 48% 83.37$ None No J7300 7300 - OUTDOOR TURF ADHESIVE BROADLOOM Pail 103.12$ 19% 83.63$ None No 179PE 4"W X 120'L TOELESS WALL BASE ROLL RESILIENT Roll 160.80$ 47% 84.72$ PVC Content No H6200 6200 - ADHESIVE DETACKIFIER BROADLOOM Pail 110.11$ 23% 85.22$ None No H620U 6200 - ADHESIVE DETACKIFIER UNITS BROADLOOM Pail 110.11$ 23% 85.22$ None No N620U ADHESIVE DETACKIFIER TILE Pail 110.11$ 23% 85.22$ None No CAA90 ECOMADE HARDWOOD ADHESIVE 4 GALLON HS Pail 138.95$ 34% 91.12$ None No 109VS SHAW 200 ‐ RESILIENT RESILIENT EA 100.00$ 9% 91.39$ None No 336VS 4" METALLIC WALL BASE ROLL RESILIENT Roll 160.80$ 43% 91.74$ PVC Content No 304VS SHAW MS RESILIENT RESILIENT 2 Gallon Pail 172.00$ 45% 93.97$ None No 02W65 GU35 WOOD & BAMBOO ADHESIVE RESILIENT EA 210.00$ 53% 99.21$ None No CA884 SHAW 35MC HS EA 202.90$ 43% 115.47$ None No LOK4S CARPET TILE - LOKDOTS ADHESIVE 1/2 SLEEVE TILE EA 225.00$ 45% 124.46$ None No 009VS 4100 - RESILIENT 4 GALLON ADHESIVE(ROLLS) RESILIENT EA 261.85$ 51% 129.12$ None No 012VS 4100‐4G ADHESIVE RESILIENT EA 261.85$ 51% 129.12$ None No UVS12 4100 - RESILIENT 4 GALLON ADHESIVE (UNITS) RESILIENT EA 261.85$ 51% 129.12$ None No CAA91 SHAW URETHANE HARDWOOD ADHESIVE 4
GALLON
HS Pail 208.37$ 29% 147.52$ None No
CAADH SHAW URE-BOND ADHESIVE 4 GALLON HS Pail 210.51$ 30% 147.52$ None No 340VS 4151 PRESSURE SENSITIVE UNIVERSAL ADHESIVE RESILIENT EA 214.94$ 25% 161.87$ None No 9150N 4151 PRESSURE SENSITIVE UNIVERSAL ADHESIVE TILE EA 214.94$ 25% 161.87$ None No F9150 4151 PRESSURE SENSITIVE UNIVERSAL ADHESIVE BROADLOOM EA 214.94$ 25% 161.87$ None No LWRX0 LOKWORX BOX TILE EA 213.96$ 24% 163.42$ None No H9000 BARRIER COAT ‐‐ FLOOR ENCAPSULATION BROADLOOM Pail 236.37$ 24% 179.65$ None No H900U 9000 - BARRIER COAT UNITS BROADLOOM Pail 236.37$ 24% 179.65$ None No N900U 9000 - BARRIER COAT UNITS TILE Pail 236.37$ 24% 179.65$ None No 00LDR LOKDOKS TILE EA 375.00$ 46% 202.80$ None No
AVEUU ADHESIVE ALTERNATIVE -- SHAW ADVANTAGE
SYSTEM UNITS
TILE Roll 409.08$ 24% 311.55$ None No
AVNET ADHESIVE ALTERNATIVE -- SHAW ADVANTAGE
SYSTEM
TILE Roll 409.08$ 24% 311.55$ None No
AVSCC ADHESIVE ALTERNATIVE -- SHAW ADVANTAGE
SYSTEM
BROADLOOM Roll 409.08$ 24% 311.55$ None No
AVSTR ADHESIVE ALTERNATIVE -- SHAW ADVANTAGE
SYSTEM
BROADLOOM Roll 409.08$ 24% 311.55$ None No CU034 CUSHIONWORX 3MM TILE Roll 386.56$ 10% 346.69$ None No DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 094VS VS‐60 VERSASHIELD 60 RESILIENT EA 897.50$ 32% 607.90$ None No 9125H MOISTURETEK BROADLOOM EA 887.18$ 22% 695.11$ None No 9125J MOISTURETEK RESILIENT EA 887.18$ 22% 695.11$ None No 9125N MOISTURETEK TILE EA 887.18$ 22% 695.11$ None No 00048 SPORT INSTALLATION KIT BROADLOOM EA 927.27$ 22% 726.54$ None No 095VS VS‐60 MBX VERSASHIELD 60 RESILIENT Roll 2,556.25$ 34% 1,688.66$ None No Hardwood
CA362 AUTHENTICITY HS SF 9.00$ 58% 3.76$ None No CA361 KINSHIP ENGINEERED WOOD HS SF 9.00$ 50% 4.54$ None No CA308 REFINED HS SF 11.00$ 50% 5.47$ None No CA350 BESPOKE HS SF 9.90$ 40% 5.90$ None No CA364 HANDCRAFTED ENGINEERED WOOD HS EA 13.00$ 51% 6.37$ None No LCSLT COLOR SEALANT HS EA 9.33$ 27% 6.80$ None No 203UV CAMARET HS SF 12.36$ 43% 7.04$ None No CAQTR QUARTER ROUND (96" LENGTH) HS EA 23.75$ 46% 12.86$ None No LCQTR QUARTER ROUND HS EA 23.75$ 46% 12.86$ None No LCSTR STAIRNOSE HS EA 23.75$ 46% 12.86$ None No LCMPR MULTI PURPOSE REDUCER HS EA 24.64$ 46% 13.34$ None No LCTM1 T- MOLDING HS EA 30.30$ 46% 16.40$ None No CATMW T - MOLDING HS EA 67.50$ 48% 34.79$ None No LCTRK MOLDING TRACK HS EA 72.50$ 46% 39.24$ None No LCSSU SILENT STEP ULTRA UNDERLAYMENT (100 SQ FT) HS Roll 56.22$ 29% 39.91$ None No CATMH T - MOLDING HS EA 82.50$ 48% 42.53$ None No CRW38 FLUSH REDUCER HS EA 85.00$ 48% 43.81$ None No CCW38 THRESHOLD HS EA 87.50$ 48% 45.10$ None No CORH2 OVERLAP REDUCER HS EA 95.00$ 48% 48.97$ None No CORW8 OVERLAP REDUCER HS EA 95.00$ 48% 48.97$ None No CRH12 FLUSH REDUCER HS EA 100.00$ 48% 51.55$ None No CSW38 FLUSH STAIRNOSE HS EA 100.00$ 48% 51.55$ None No LCTMD T- MOLDING HS EA 102.50$ 46% 55.47$ None No COSH2 OVERLAP STAIRNOSE HS EA 130.00$ 48% 67.01$ None No CSH12 FLUSH STAIRNOSE HS EA 137.50$ 49% 70.00$ None No LC084 SILENT STEP ULTRA JUMBO ROLL (1000 SQ.FT.) HS Roll 511.89$ 31% 354.12$ None No US Floors
022UV STRATUM VORTEX RESILIENT SF 5.90$ 55% 2.66$ PVC Content YES, ISO14025 Industry Average EPD
023UV STRATUM 500 - 50050DLV500 RESILIENT SF 7.07$ 59% 2.87$ PVC Content YES, ISO14025 Industry Average EPD
024UV STRATUM 700 - 70050DLV700 RESILIENT SF 7.07$ 59% 2.87$ PVC Content YES, ISO14025 Industry Average EPD
032UV STRATUM 1200 RESILIENT SF 7.07$ 59% 2.87$ PVC Content YES, ISO14025 Industry Average EPD
033UV STRATUM 1800 RESILIENT SF 6.43$ 55% 2.87$ PVC Content YES, ISO14025 Industry Average EPD
058UV STRATUM DEFINED - 50DLV3001 RESILIENT SF 7.01$ 54% 3.24$ PVC Content YES, ISO14025 Industry Average EPD
055UV STRATUM LINEAR RESILIENT SF 6.80$ 48% 3.53$ PVC Content YES, ISO14025 Industry Average EPD
034UV STRATUM XL RESILIENT SF 8.33$ 55% 3.71$ PVC Content YES, ISO14025 Industry Average EPD
053UV STRATUM EIRIS RESILIENT SF 8.33$ 55% 3.79$ PVC Content YES, ISO14025 Industry Average EPD
205UV MIDTOWN REVIVAL SMOOTH RESILIENT SF 11.00$ 41% 5.50$ PVC Content YES, ISO14025 Industry Average EPD
206UV MIDTOWN REVIVAL HANDSCRAPED RESILIENT SF 10.00$ 45% 6.50$ PVC Content YES, ISO14025 Industry Average EPD
204UV PALISADES RESILIENT SF 20.00$ 51% 9.89$ PVC Content YES, ISO14025 Industry Average EPD
01W29 QUARTER ROUND CORETEC XL RESILIENT EA 50.05$ 47% 26.49$ PVC Content No DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 01W25 QUARTER ROUND CORETEC 1800 RESILIENT EA 45.50$ 41% 27.06$ PVC Content No 01A02 BABY THRESHOLD CORETEC 1800 RESILIENT EA 45.50$ 39% 27.61$ PVC Content No 01W40 QUARTER ROUND CORETEC EIRIS RESILIENT EA 50.05$ 35% 32.44$ PVC Content No 01W27 QUARTER ROUND CORETEC 500 RESILIENT EA 50.05$ 35% 32.45$ PVC Content No 01W50 REDUCER CORETEC 1800 RESILIENT EA 45.50$ 29% 32.47$ PVC Content No 02W22 T-MOLD CORETEC 1800 RESILIENT EA 45.50$ 29% 32.47$ PVC Content No 01W74 STAIR NOSE CORETEC 1800 RESILIENT EA 54.25$ 39% 33.20$ PVC Content No 02W20 T-MOLD CORETEC 1200 RESILIENT EA 50.05$ 33% 33.46$ PVC Content No 01W08 BABY THRESHOLD CORETEC VORTEX RESILIENT EA 50.05$ 33% 33.62$ PVC Content No 02W57 T-MOLD CORETEC EIRIS RESILIENT EA 50.05$ 33% 33.63$ PVC Content No 01V64 REDUCER CORETEC LINEAR RESILIENT EA 50.05$ 33% 33.69$ PVC Content No 01V13 BABY THRESHOLD CORETEC LINEAR RESILIENT EA 50.05$ 32% 33.88$ PVC Content No 02V56 T-MOLD CORETEC LINEAR RESILIENT EA 50.05$ 32% 33.90$ PVC Content No 01W58 REDUCER CORETEC VORTEX RESILIENT EA 50.05$ 32% 33.92$ PVC Content No 01W04 BABY THRESHOLD CORETEC XL RESILIENT EA 50.05$ 32% 33.95$ PVC Content No 02W28 T-MOLD CORETEC 700 RESILIENT EA 50.05$ 32% 33.97$ PVC Content No 02W30 T-MOLD CORETEC VORTEX RESILIENT EA 50.05$ 32% 33.98$ PVC Content No 02W24 T-MOLD CORETEC 500 RESILIENT EA 50.05$ 32% 34.01$ PVC Content No 01W02 BABY THRESHOLD CORETEC 500 RESILIENT EA 50.05$ 32% 34.04$ PVC Content No 01W54 REDUCER CORETEC 500 RESILIENT EA 50.05$ 32% 34.13$ PVC Content No 01W48 REDUCER CORETEC 1200 RESILIENT EA 50.05$ 32% 34.15$ PVC Content No 01W14 BABY THRESHOLD CORETEC EIRIS RESILIENT EA 50.05$ 32% 34.16$ PVC Content No 01X54 REDUCER CORETEC XL RESILIENT EA 50.05$ 32% 34.27$ PVC Content No 01V18 BABY THRESHOLD CORETEC DEFINED RESILIENT EA 50.05$ 31% 34.66$ PVC Content No 01W06 BABY THRESHOLD CORETEC 700 RESILIENT EA 50.05$ 31% 34.69$ PVC Content No 02W61 T-MOLD CORETEC DEFINED RESILIENT EA 50.05$ 31% 34.69$ PVC Content No 01V69 REDUCER CORETEC DEFINED RESILIENT EA 50.05$ 30% 34.92$ PVC Content No 01W31 QUARTER ROUND CORETEC 700 RESILIENT EA 50.05$ 30% 34.96$ PVC Content No 01W65 REDUCER CORETEC EIRIS RESILIENT EA 50.05$ 30% 35.11$ PVC Content No 01W33 QUARTER ROUND CORETEC VORTEX RESILIENT EA 50.05$ 29% 35.46$ PVC Content No 01W56 REDUCER CORETEC 700 RESILIENT EA 50.05$ 26% 37.28$ PVC Content No 01W56 REDUCER CORETEC 700 RESILIENT EA 50.05$ 26% 37.28$ PVC Content No 01V89 STAIR NOSE CORETEC LINEAR RESILIENT EA 59.68$ 36% 38.11$ PVC Content No 01V39 QUARTER ROUND CORETEC LINEAR RESILIENT EA 50.05$ 23% 38.76$ PVC Content No 01V45 QUARTER ROUND CORETEC DEFINED RESILIENT EA 50.05$ 23% 38.76$ PVC Content No 01W00 BABY THRESHOLD CORETEC 1200 RESILIENT EA 50.05$ 23% 38.76$ PVC Content No 01W22 QUARTER ROUND CORETEC 1200 RESILIENT EA 50.05$ 23% 38.76$ PVC Content No 01X78 STAIR NOSE CORETEC XL RESILIENT EA 59.68$ 33% 40.28$ PVC Content No 01V94 STAIR NOSE CORETEC DEFINED RESILIENT EA 59.68$ 32% 40.75$ PVC Content No 01W80 STAIR NOSE CORETEC 700 RESILIENT EA 59.68$ 31% 41.23$ PVC Content No 01W82 STAIR NOSE CORETEC VORTEX RESILIENT EA 59.68$ 31% 41.28$ PVC Content No 01W78 STAIR NOSE CORETEC 500 RESILIENT EA 59.68$ 31% 41.32$ PVC Content No 01W90 STAIR NOSE CORETEC EIRIS RESILIENT EA 59.68$ 30% 42.02$ PVC Content No 01W72 STAIR NOSE CORETEC 1200 RESILIENT EA 59.68$ 23% 46.21$ PVC Content No The products above marked with an * are solution dyed, however, they are not 100% solution dyed. We believe these products will perform according to your requirements.
Broadloom products listed above do not meet UCOP's recycled content requirements.
Pricing above is effective from October 1, 2019 - September 30, 2020.
ACH Net 60
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F Attachment B - University of California Price Schedule
Style
Number Style Name Type UOM List Discount
Off List Price Chemicals of Concern EPD
Broadloom
I0442 RESPITE CLASSICBAC® BROADLOOM SY 16.29$ 53% 7.62$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0249 STRIDE CLASSICBAC® BROADLOOM SY 15.12$ 47% 8.03$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0250 PACE CLASSICBAC® BROADLOOM SY 15.09$ 47% 8.06$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0347 ABODE CLASSICBAC® BROADLOOM SY 15.75$ 48% 8.13$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0120 SCHOLASTIC II-26 CLASSICBAC® BROADLOOM SY 16.57$ 51% 8.20$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0251 GAIT CLASSICBAC® BROADLOOM SY 15.08$ 45% 8.24$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
Z6432 BUY IN CLASSICBAC® BROADLOOM SY 17.20$ 51% 8.36$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
Z6434 TRADE UP CLASSICBAC® BROADLOOM SY 17.22$ 51% 8.36$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0162 OPPORTUNITY KNOCKS CLASSICBAC® BROADLOOM SY 18.27$ 54% 8.44$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0527 MOTIF BROADLOOM SY 16.29$ 48% 8.51$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0124 WORK IT CLASSICBAC® BROADLOOM SY 17.95$ 52% 8.58$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
Z6436 PAY OFF CLASSICBAC® BROADLOOM SY 17.69$ 51% 8.58$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0464 HOMESPUN CLASSICBAC® BROADLOOM SY 15.39$ 44% 8.64$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0366 WORD OF MOUTH CLASSICBAC® BROADLOOM SY 17.46$ 48% 9.12$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0522 CANTILEVER BROADLOOM SY 18.09$ 49% 9.23$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0523 CENTERLINE BROADLOOM SY 18.09$ 49% 9.23$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0272 30'S III CLASSICBAC® BROADLOOM SY 17.40$ 47% 9.25$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0246 * APPROACH CLASSICBAC® BROADLOOM SY 18.09$ 48% 9.32$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0248 TECHNIQUE CLASSICBAC® BROADLOOM SY 18.13$ 49% 9.33$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0101 HOMEROOM II‐26 ULTRALOC® PATTERN BROADLOOM SY 18.36$ 49% 9.34$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0368 SEAL THE DEAL CLASSICBAC® BROADLOOM SY 19.57$ 52% 9.45$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0369 PUBLIC AFFAIRS CLASSICBAC® BROADLOOM SY 17.46$ 44% 9.73$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0068 SOCRATES II‐26 ULTRALOC® PATTERN BROADLOOM SY 18.37$ 47% 9.78$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0200 WINDSWEPT CLASSICBAC® BROADLOOM SY 19.05$ 49% 9.79$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0528 ESTATE BROADLOOM SY 19.26$ 49% 9.79$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0121 SCHOLASTIC II‐28 ULTRALOC® PATTERN BROADLOOM SY 18.78$ 48% 9.85$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0440 COMMIT ULTRALOC® PATTERN BROADLOOM SY 18.34$ 46% 9.87$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0351 HOMEROOM V.3.0 ULTRALOC PATTERN BROADLOOM SY 18.27$ 44% 10.22$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0069 SOCRATES II‐28 ULTRALOC® PATTERN BROADLOOM SY 20.03$ 49% 10.23$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0367 SHAKE ON IT CLASSICBAC® BROADLOOM SY 19.57$ 47% 10.28$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0485 CAMBER ULTRALOC® BROADLOOM SY 17.73$ 41% 10.51$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0109 STRUT YOUR STUFF ULTRALOC® PATTERN BROADLOOM SY 24.02$ 56% 10.56$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F I0441 SUCCEED ULTRALOC® PATTERN BROADLOOM SY 19.57$ 46% 10.59$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0104 BEST FOOT FORWARD ULTRALOC® PATTERN BROADLOOM SY 22.78$ 53% 10.65$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0439 DECIDE ULTRALOC® PATTERN BROADLOOM SY 20.81$ 49% 10.66$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0164 * BIG SPLASH ULTRALOC® PATTERN BROADLOOM SY 21.05$ 49% 10.73$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0487 INTERVAL ULTRALOC® BROADLOOM SY 17.73$ 39% 10.80$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0486 INTERCEPT ULTRALOC® BROADLOOM SY 17.73$ 39% 10.83$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0129 * NIGHT MOVES ULTRALOC® PATTERN BROADLOOM SY 25.52$ 57% 10.89$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0131 COLOR YOUR WORLDULTRALOC® PATTERN BROADLOOM SY 22.21$ 51% 10.92$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0147 FAMOUS LAST WORDS II ULTRALOC® PATTERN BROADLOOM SY 24.96$ 55% 11.27$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0148 HEADLINES II ULTRALOC® PATTERN BROADLOOM SY 24.92$ 55% 11.27$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0157 * TWIST & SHOUT II ULTRALOC® PATTERN BROADLOOM SY 24.93$ 55% 11.27$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0444 TRIED CLASSICBAC® BROADLOOM SY 25.30$ 54% 11.56$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0443 TESTED CLASSICBAC® BROADLOOM SY 24.73$ 52% 11.77$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0445 TRUE CLASSICBAC® BROADLOOM SY 25.30$ 53% 11.86$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0202 SABRE CLASSICBAC® BROADLOOM SY 26.51$ 55% 11.95$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0352 HOMEROOM V 3.0 ECOWORX®
PERFORMANCE BROADLOOM
BROADLOOM SY 25.01$ 49% 12.73$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0165 * BIG SPLASH ECOWORX® PERFORMANCE
BROADLOOM
BROADLOOM SY 28.70$ 51% 13.92$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0203 COLOR CHOICE ULTRALOC® PATTERN BROADLOOM SY 40.23$ 62% 15.39$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0402 AFICIONADO ECOWORX® PERFORMANCE
BROADLOOM
BROADLOOM SY 27.21$ 41% 15.96$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0498 BASQUE ULTRALOC® BROADLOOM SY 32.98$ 48% 17.31$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0497 ARAGON ULTRALOC® BROADLOOM SY 32.98$ 46% 17.70$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0413 HALLO ULTRALOC® PATTERN BROADLOOM SY 36.34$ 50% 18.01$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0415 CIAO ULTRALOC® PATTERN BROADLOOM SY 36.34$ 48% 19.06$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0414 NIHAO ULTRALOC® PATTERN BROADLOOM SY 36.34$ 46% 19.52$ Mineral based non-halogenated flame retardant for regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0398 BOHEMIAN ECOWORX® PERFORMANCE BROADLOOM BROADLOOM SY 42.41$ 52% 20.37$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
Walk-off
I0306 ENTRY POINT MODULAR TILE SY 55.19$ 45% 30.54$ Trace amounts of Fly Ash from Recycled Content No I0376 PRADO ECOWORX® PERFORMANCE
BROADLOOM
BROADLOOM SY 57.35$ 46% 31.02$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
Tile
I0461 SKILL MODULAR TILE SY 23.31$ 52% 11.21$ Mineral based non-halogenated flame retardant for regulatory requirements No I0459 REASON MODULAR TILE SY 23.31$ 50% 11.54$ Mineral based non-halogenated flame retardant for regulatory requirements No I0460 LOGIC MODULAR TILE SY 23.31$ 50% 11.56$ Mineral based non-halogenated flame retardant for regulatory requirements No I0499 NATURAL FORM MODULAR TILE SY 25.56$ 48% 13.19$ Mineral based non-halogenated flame retardant for regulatory requirements No I0501 INSTINCT MODULAR TILE SY 25.56$ 48% 13.20$ Mineral based non-halogenated flame retardant for regulatory requirements No I0500 REBALANCE MODULAR TILE SY 25.56$ 47% 13.45$ Mineral based non-halogenated flame retardant for regulatory requirements No I0301 VIM MODULAR TILE SY 31.90$ 57% 13.85$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F I0380 FUTURA MODULAR TILE SY 30.15$ 53% 14.30$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0379 ORBITAL MODULAR TILE SY 30.15$ 51% 14.86$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0515 EASTERN FACADE TILE SY 30.24$ 51% 14.95$ Mineral based non-halogenated flame retardant for regulatory requirements No I0516 SUBURBAN ABSTRACT TILE SY 30.24$ 51% 14.95$ Mineral based non-halogenated flame retardant for regulatory requirements No I0517 EDGELAND TILE SY 30.24$ 51% 14.95$ Mineral based non-halogenated flame retardant for regulatory requirements No I0291 EXPERIENCE MODULAR TILE SY 29.95$ 50% 14.99$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0227 EASY ON THE EYES MODULAR TILE SY 29.78$ 49% 15.13$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0226 MOVING ON UP MODULAR TILE SY 29.78$ 49% 15.26$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0290 THOUGHT MODULAR TILE SY 30.25$ 49% 15.47$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0302 VIVID MODULAR TILE SY 32.22$ 52% 15.53$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0280 YIELD MODULAR TILE SY 33.86$ 53% 15.89$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0125 SCHOLASTIC II MODULAR TILE SY 33.43$ 52% 16.02$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0481 FUTURA/ECOLOGIX TILE SY 32.45$ 50%
16.24$
Trace amounts of Fly Ash from Recycled Content
Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0279 FLEX MODULAR TILE SY 33.86$ 52% 16.42$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0239 SPEAK IN COLOR MODULAR TILE SY 36.15$ 54% 16.55$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0356 SIGN OFF MODULAR TILE SY 32.91$ 50% 16.59$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0355 DOWNLOAD MODULAR TILE SY 32.91$ 49% 16.62$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0518 FORMWORK TILE SY 34.38$ 51% 17.01$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0520 TRANSVERSE TILE SY 34.38$ 51% 17.01$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0483 ORBITAL ECOLOGIX TILE SY 32.45$ 47% 17.06$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0383 LINEA 2 MODULAR TILE SY 32.81$ 48% 17.21$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0354 LOG IN MODULAR TILE SY 32.91$ 48% 17.23$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0448 COLOR POP 12X48 MODULAR TILE SY 34.32$ 49% 17.40$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0096 TWEED MODULAR TILE SY 37.24$ 53% 17.47$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0482 FUTURA/ECOLOGIX ES TILE SY 36.69$ 52% 17.48$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0381 COLOR POP MODULAR TILE SY 32.81$ 47% 17.49$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F I0519 SCAFFOLD TILE SY 34.38$ 49% 17.52$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0110 COLOR YOUR WORLD MODULAR TILE SY 37.36$ 52% 17.77$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0382 COLOR BLOCK MODULAR TILE SY 32.81$ 46% 17.77$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0126 SOCRATES II‐26 MODULAR TILE SY 38.40$ 54% 17.84$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0386 DISPLACE MODULAR TILE SY 37.35$ 52% 17.85$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
Z6474 INTRINSIC MODULAR TILE SY 36.35$ 51% 17.94$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0410 * DECATHLON MODULAR TILE SY 37.63$ 52% 18.08$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0447 COLOR BLOCK 12X48 MODULAR TILE SY 34.04$ 47% 18.18$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0353 HOMEROOM V.3.0 MODULAR TILE SY 35.18$ 48% 18.24$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0484 ORBITAL ECOLOGIX ES TILE SY 36.78$ 49% 18.59$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0465 RISE MODULAR TILE SY 37.27$ 50% 18.62$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0467 SLOPE MODULAR TILE SY 37.27$ 50% 18.62$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0449 PIVOT POINT MODULAR TILE SY 38.57$ 51% 18.73$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0450 VAULT MODULAR TILE SY 38.68$ 51% 18.95$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0357 AIRE SKINNY MODULAR TILE SY 40.38$ 53% 18.99$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0358 AURA SKINNY MODULAR TILE SY 40.38$ 53% 18.99$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0404 AIRE 9" X 36" MODULAR TILE SY 40.38$ 53% 18.99$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
Z6476 LIQUID MODULAR TILE SY 40.49$ 53% 19.00$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0489 REALIZE MODULAR TILE SY 37.17$ 49% 19.11$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0466 RUN MODULAR TILE SY 37.27$ 49% 19.18$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0490 POSSIBLE MODULAR TILE SY 37.17$ 48% 19.19$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
Z6475 STUDIO MODULAR TILE SY 39.72$ 52% 19.26$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0491 ACHIEVE MODULAR TILE SY 37.17$ 47% 19.62$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0240 SPEAK IN DESIGN MODULAR TILE SY 36.15$ 46% 19.67$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F I0343 * 3K MODULAR TILE SY 42.83$ 54% 19.71$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0344 * 5K MODULAR TILE SY 41.60$ 53% 19.71$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0345 * 10K MODULAR TILE SY 42.83$ 54% 19.71$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0166 * BIG SPLASH MODULAR TILE SY 45.10$ 56% 19.72$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0359 ETHEREAL MODULAR TILE SY 40.38$ 51% 19.87$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
Z6477 LOFT MODULAR TILE SY 39.67$ 50% 20.02$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
Z6473 DWELL MODULAR TILE SY 40.48$ 50% 20.23$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0405 WORK. STUDY. PLAY. 24X24 MODULAR TILE SY 37.91$ 46% 20.45$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0283 COOL RAIN MODULAR TILE SY 42.13$ 50% 21.05$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0425 WORK. STUDY. PLAY. 12X48 MODULAR TILE SY 41.56$ 49% 21.21$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0286 EARTHEN WEAVE MODULAR TILE SY 42.13$ 50% 21.24$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0505 ARTCLOTH MODULAR TILE SY 45.83$ 53% 21.50$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0119 * DAZZLE MODULAR TILE SY 48.73$ 56% 21.61$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0349 FLUTTER MODULAR TILE SY 45.36$ 52% 21.67$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0285 CITY FLORA MODULAR TILE SY 42.13$ 48% 21.75$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0284 CLEAN LINES MODULAR TILE SY 42.13$ 48% 22.08$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0385 DISRUPT MODULAR TILE SY 48.47$ 54% 22.11$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0426 CUBE & COLOUR 24X24 MODULAR TILE SY 47.80$ 54% 22.20$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0348 DART MODULAR TILE SY 45.36$ 50% 22.64$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0118 * RAZZLE MODULAR TILE SY 45.03$ 49% 22.94$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0384 DISMANTLE MODULAR TILE SY 48.47$ 52% 23.03$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0506 GLOBAL HAND MODULAR TILE SY 45.83$ 49% 23.16$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0350 IN FLIGHT MODULAR TILE SY 46.53$ 50% 23.20$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0427 CUBE & COLOUR 12X48 MODULAR TILE SY 47.80$ 51% 23.24$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F I0507 MICRO-WEAVE MODULAR TILE SY 45.83$ 48% 23.90$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0457 INVERNESS MODULAR TILE SY 49.06$ 51% 23.91$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0469 BACKLIT 18X36 MODULAR TILE SY 50.33$ 52% 23.95$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0455 ABERDEEN MODULAR TILE SY 49.06$ 51% 24.09$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0421 ALLOY SHIMMER MODULAR TILE SY 48.87$ 50% 24.21$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0456 EDINBURGH MODULAR TILE SY 49.06$ 51% 24.25$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0204 COLOR CHOICE MODULAR TILE SY 51.89$ 53% 24.26$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0468 BACKLIT 9X36 MODULAR TILE SY 50.33$ 52% 24.38$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0470 NOCTURNE 9X36 MODULAR TILE SY 52.86$ 54% 24.38$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0514 REACT MODULAR TILE SY 48.87$ 50% 24.42$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0513 RELIC MODULAR TILE SY 48.87$ 49% 24.78$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0471 COLOR FILTER 9X36 MODULAR TILE SY 50.33$ 51% 24.84$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0393 SHADOWGRAPH 9" X 36" MODULAR TILE SY 50.33$ 50% 24.93$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0422 METALLIC ALCHEMY MODULAR TILE SY 48.87$ 49% 25.00$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0204
COLOR CHOICE FACET MODULAR -
TILE SY 51.89$ 48% 27.23$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0428 CUBE & COLOUR FACET MODULAR TILE SY 55.39$ 50% 27.46$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0373 GEOMETRIX FACET TILE SY 57.24$ 52% 27.68$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0372 OPTIX FACET MODULAR TILE SY 57.24$ 51% 28.10$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0371 FABRIX FACET MODULAR TILE SY 57.24$ 50% 28.41$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0512 ETCHED MODULAR TILE SY 55.89$ 47% 29.90$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0305 ON THE RIGHT FOOT MODULAR TILE SY 55.19$ 46% 29.93$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0304 WALK RIGHT IN II MODULAR TILE SY 55.19$ 45% 30.35$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
I0316 PASEO MODULAR TILE SY 65.44$ 51% 32.22$ Trace amounts of Fly Ash from Recycled Content Mineral based non-halogenated flame retardant for
regulatory requirements
Yes, ISO14025 Product Specific
EPD
Resilient
I342V TIMBER GROVE 8 RESILIENT SF 1.90$ 52% 0.91$ PVC Content YES, ISO14025 Industry Average EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F I420V TIMBER GROVE II 12 MIL RESILIENT SF 3.00$ 62% 1.15$ PVC Content YES, ISO14025 Industry Average EPD
I300V WOODLAND VIEW RESILIENT SF 2.86$ 57% 1.24$ PVC Content YES, ISO14025 Industry Average EPD
I323V TIMBER GROVE 12 RESILIENT SF 3.30$ 62% 1.25$ PVC Content YES, ISO14025 Industry Average EPD
I200V HIGHLAND FOREST 4" RESILIENT SF 4.78$ 65% 1.68$ PVC Content YES, ISO14025 Industry Average EPD
I800V HIGHLAND FOREST 6" RESILIENT SF 4.78$ 65% 1.68$ PVC Content YES, ISO14025 Industry Average EPD
I426V CMYK RESILIENT SF 4.00$ 52% 1.93$ PVC Content YES, ISO14025 Industry Average EPD
I421V TIMBER GROVE II 20MIL RESILIENT SF 5.50$ 64% 1.99$ PVC Content YES, ISO14025 Industry Average EPD
I206V NORTH RIDGE 4" RESILIENT SF 4.77$ 58% 2.00$ PVC Content YES, ISO14025 Industry Average EPD
I207V NORTH RIDGE 6" RESILIENT SF 4.77$ 58% 2.00$ PVC Content YES, ISO14025 Industry Average EPD
I325V TIMBER GROVE 20 RESILIENT SF 5.50$ 63% 2.02$ PVC Content YES, ISO14025 Industry Average EPD
I476V CREATIVE CODE RESILIENT SF 4.23$ 52% 2.04$ PVC Content YES, ISO14025 Industry Average EPD
I333V AGGREGATE RESILIENT SF 4.20$ 51% 2.06$ PVC Content YES, ISO14025 Industry Average EPD
I334V DISSIPATE RESILIENT SF 4.20$ 51% 2.06$ PVC Content YES, ISO14025 Industry Average EPD
I322V STRATIFIED+ 12" X 24" RESILIENT SF 5.00$ 58% 2.08$ PVC Content YES, ISO14025 Industry Average EPD
I312V TYPEFACE RESILIENT SF 4.00$ 48% 2.09$ PVC Content YES, ISO14025 Industry Average EPD
I313V CHARTED RESILIENT SF 4.00$ 48% 2.10$ PVC Content YES, ISO14025 Industry Average EPD
I700V STRATIFIED RESILIENT SF 4.63$ 54% 2.11$ PVC Content YES, ISO14025 Industry Average EPD
I311V LETTERPRESS RESILIENT SF 4.00$ 47% 2.12$ PVC Content YES, ISO14025 Industry Average EPD
I321V Stratified + RESILIENT SF 5.00$ 57% 2.14$ PVC Content YES, ISO14025 Industry Average EPD
I438V TIMBER GROVE II 30 MIL RESILIENT SF 5.10$ 57% 2.17$ PVC Content YES, ISO14025 Industry Average EPD
I318V ARBOR CREST RESILIENT SF 5.67$ 56% 2.49$ PVC Content YES, ISO14025 Industry Average EPD
I405V VININGS RESILIENT SF 5.00$ 50% 2.52$ PVC Content YES, ISO14025 Industry Average EPD
I418V WITHDRAW RESILIENT SF 5.00$ 49% 2.57$ PVC Content YES, ISO14025 Industry Average EPD
I462V MONOCHROME MATTE RESILIENT SF 5.00$ 48% 2.58$ PVC Content YES, ISO14025 Industry Average EPD
I463V MONOCHROME GLOSS RESILIENT SF 5.00$ 48% 2.58$ PVC Content YES, ISO14025 Industry Average EPD
I464V SURFACE TONE RESILIENT SF 5.00$ 48% 2.58$ PVC Content YES, ISO14025 Industry Average EPD
I417V REMOVE RESILIENT SF 5.00$ 48% 2.60$ PVC Content YES, ISO14025 Industry Average EPD
I439V CROSSOVER RESILIENT SF 5.15$ 47% 2.72$ PVC Content YES, ISO14025 Industry Average EPD
I466V SPLITWOOD RESILIENT SF 6.00$ 55% 2.73$ PVC Content YES, ISO14025 Industry Average EPD
I478V MOLTEN RESILIENT SF 6.00$ 55% 2.73$ PVC Content YES, ISO14025 Industry Average EPD
I479V OXIDIZED RESILIENT SF 6.00$ 55% 2.73$ PVC Content YES, ISO14025 Industry Average EPD
I465V TIMBER GROVE II WPC 20 RESILIENT SF 5.49$ 48% 2.86$ PVC Content YES, ISO14025 Industry Average EPD
I600V CLICK REFRESH RESILIENT SF 6.74$ 56% 2.98$ PVC Content YES, ISO14025 Industry Average EPD
I424V ADESA RESILIENT SF 6.60$ 55% 2.99$ PVC Content YES, ISO14025 Industry Average EPD
I440V CROSSOVER CLICK RESILIENT SF 6.42$ 51% 3.12$ PVC Content YES, ISO14025 Industry Average EPD
I336V WOOD PLANX 9" X 36" RESILIENT SF 8.57$ 51% 4.19$ PVC Content YES, ISO14025 Industry Average EPD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F I447V ENRICH PLANK BIOBASED RESILIENT SF 9.00$ 53% 4.21$ None Yes, ISO14025 Product Specific EPD
I316V WOOD PLANX RESILIENT SF 8.40$ 50% 4.23$ PVC Content YES, ISO14025 Industry Average EPD
I314V METALLIX RECTANGLE RESILIENT SF 8.40$ 49% 4.28$ PVC Content YES, ISO14025 Industry Average EPD
I446V MEANING BIOBASED RESILIENT SF 9.00$ 52% 4.29$ None Yes, ISO14025 Product Specific EPD
I337V METALLIX 9" X 36" RESILIENT SF 8.40$ 49% 4.30$ PVC Content YES, ISO14025 Industry Average EPD
I315V METALLIX (FACET) RESILIENT SF 8.40$ 47% 4.46$ PVC Content YES, ISO14025 Industry Average EPD
I346V ADMIX 12" X 12" RESILIENT SF 11.00$ 54% 5.03$ PVC Content YES, ISO14025 Industry Average EPD
I429V ADMIX ENCORE GLOSS RESILIENT SF 11.00$ 51% 5.37$ PVC Content YES, ISO14025 Industry Average EPD
I452V ADMIX ENCORE MATTE RESILIENT SF 11.00$ 51% 5.37$ PVC Content YES, ISO14025 Industry Average EPD
I450V ADMIX MATTE 12" X 12" RESILIENT SF 11.00$ 49% 5.60$ PVC Content YES, ISO14025 Industry Average EPD
I508V ADMIX 18X36 RESILIENT SF 11.00$ 49% 5.66$ PVC Content YES, ISO14025 Industry Average EPD
I451V ADMIX MATTE 36" X 36" RESILIENT SF 12.00$ 50% 6.05$ PVC Content YES, ISO14025 Industry Average EPD
I347V ADMIX 36" X 36" RESILIENT SF 12.00$ 48% 6.27$ PVC Content YES, ISO14025 Industry Average EPD
I422V HOLISTIC RESILIENT SY 43.26$ 45% 23.73$ PVC Content YES, ISO14025 Industry Average EPD
I320V ORGANIC HUE RESILIENT SY 51.50$ 52% 24.71$ PVC Content YES, ISO14025 Industry Average EPD
1319V BROOKWOOD + RESILIENT SY 46.35$ 46% 25.23$ PVC Content YES, ISO14025 Industry Average EPD
I404V IVY WALK RESILIENT SY 45.32$ 43% 25.78$ PVC Content YES, ISO14025 Industry Average EPD
I448V ENRICH SHEET BIOBASED RESILIENT SY 72.00$ 52% 34.31$ None Yes, ISO14025 Product Specific EPD
306VS CADBERRY 4"W X 120'L COVE BASE ROLL RESILIENT Roll 160.80$ 51% 78.39$ PVC Content No S127V 4"W X 120'L WALL BASE ROLL RESILIENT Roll 160.80$ 51% 78.67$ PVC Content No S168V 4"W X 120'L TOELESS WALL BASE ROLL RESILIENT Roll 160.80$ 51% 78.67$ PVC Content No S155V SLOT RESILIENT Box 115.76$ 28% 82.91$ PVC Content YES, ISO14025 Industry Average EPD
S154V STRAIGHT RESILIENT Box 115.76$ 16% 96.75$ PVC Content No S167V ADMIX WELD ROD RESILIENT Roll 200.00$ 43% 114.30$ PVC Content No S109V HUSH II UNDERLAYMENT RESILIENT EA 319.88$ 44% 178.86$ None No Sports Flooring
I208V BOUNCE BACK RESILIENT SY 54.73$ 41% 32.02$ PVC Content No S126V BOUNCE BACK WELD ROD RESILIENT Roll 119.60$ 49% 60.81$ PVC Content No Adhesives
8300D BROADLOOM MOISTURE IMPERVIOUS SEAM
SEALER
BROADLOOM EA 8.08$ 12% 7.14$ None No S138V TRANSITION TAPE RESILIENT EA 16.00$ 44% 8.92$ None No 4000D BROADLOOM SEAM SEALERS BROADLOOM EA 13.04$ 23% 10.08$ None No S104V RESILIENT SEAM SEALER RESILIENT EA 23.53$ 27% 17.20$ None No S207V ADMIX 20" MAROON DEEP SCRUB PAD (RESALE) RESILIENT Box 24.26$ 23% 18.76$ None No S133V WALL BASE 1 GALLON ADHESIVE RESILIENT EA 42.00$ 48% 21.76$ None No 5001P 5001 - CARPET TILE STANDARD ADHESIVE TILE Pail 26.73$ 17% 22.08$ None No 118PM ADMIX 1 QUART GLOSS FINISH (RESALE) EA 28.75$ 23% 22.23$ None No 115PM ADMIX 1 QUART DEEP SCRUB CLEANER (RESALE) EA 34.49$ 23% 26.67$ None No S107V SHAW S150 SPRAY ADHESIVE RESILIENT EA 54.84$ 43% 31.43$ None No S108V S150 - RESILIENT SPRAY (ROLLS) RESILIENT EA 54.84$ 43% 31.43$ None No 1200D MULTI‐PURPOSE ADHESIVE BROADLOOM Pail 47.10$ 28% 33.94$ None No 1000D BROADLOOM ADHESIVE BROADLOOM Pail 47.10$ 27% 34.22$ None No S101V BROOKWOOD (PATCRAFT) WELD ROD RESILIENT Roll 74.20$ 49% 37.57$ PVC Content No S122V GROUNDWORKS RESILIENT Roll 75.00$ 45% 41.61$ None No 1036D SUPERIOR GRADE MULTIPURPOSE ADHESIVE
CONTAINING FLORSEPT AATC174
BROADLOOM Pail 56.72$ 26% 42.19$ Added Antimicrobial No S105V 4100 - RESILIENT 1 GALLON ADHESIVE(UNITS) RESILIENT Pail 79.88$ 46% 43.32$ None No S106V SHAW 4100‐1G RESILIENT Pail 79.88$ 46% 43.32$ None No DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F 3800D 3800 - UNIVERSAL INDOOR/OUTDOOR ADHESIVE BROADLOOM Pail 58.33$ 23% 45.04$ None No I0433 3800 - UNIVERSAL INDOOR/OUTDOOR ADHESIVE TILE Pail 58.33$ 23% 45.04$ None No 3600D ECO FLOR SEPT ADHESIVE BROADLOOM Pail 61.26$ 24% 46.26$ Added Antimicrobial No S114V VSM VERSASHIELD 2" TAPE RESILIENT Roll 71.25$ 33% 48.08$ None No 9050D CARPET TILE FLOOR PRIMER BROADLOOM Pail 95.69$ 43% 54.32$ None No 905DU 9050 - BARRIER COAT UNITS TILE Pail 95.69$ 43% 54.32$ None No S124V 9050 RESILIENT FLOOR PRIMER (UNITS) RESILIENT Pail 95.69$ 43% 54.32$ None No S125U RESILIENT FLOOR PRIMER RESILIENT Pail 95.69$ 43% 54.32$ None No S125V 9050 RESILIENT FLOOR PRIMER (ROLLS) RESILIENT Pail 95.69$ 43% 54.32$ None No S115V VSM MBX VERSASHIELD 2.5" TAPE (ROLLS) RESILIENT Roll 88.75$ 33% 59.54$ None No S116V VSM VERSASHIELD 4" DS TAPE RESILIENT Roll 86.25$ 31% 59.54$ None No 03LDA LOKDOTS APPLICATOR TILE EA 82.10$ 23% 63.40$ None No 117PM ADMIX 1 GALLON GLOSS SURFACE TREATMENT (RESALE) EA 85.42$ 23% 66.04$ None No S132V WALL BASE TUBE ADHESIVE RESILIENT Box 134.00$ 49% 67.96$ None No 5000P 5000 PRESSURE SENSITIVE TILE ADHESIVE TILE Pail 94.22$ 24% 71.81$ None No 5100P 5100 ‐ PRESSURE SENSITIVE ADHESIVE TILE Pail 94.22$ 24% 71.81$ None No 5036P 5036 ‐ TILE ADHESIVE W/ ANTIMICROBIAL TILE Pail 99.68$ 23% 76.62$ Added Antimicrobial No S131V MM800 4 GALLON RESILIENT 4 Gallon Pail 160.00$ 48% 83.37$ None No 114PM ADMIX 1 GALLON DEEP SCRUB CLEANER (RESALE) EA 110.02$ 23% 85.07$ None No 6200D 6200 - ADHESIVE DETACKIFIER BROADLOOM Pail 110.11$ 23% 85.22$ None No 620DU ADHESIVE DETACKIFIER TILE Pail 110.11$ 23% 85.22$ None No S123V SHAW 200 ‐ RESILIENT RESILIENT EA 100.00$ 9% 91.39$ None No S171V SHAW MS RESILIENT RESILIENT 2 Gallon Pail 172.00$ 45% 93.97$ None No LOK4T CARPET TILE - LOKDOTS ADHESIVE 1/2 SLEEVE TILE EA 225.00$ 45% 124.46$ None No S102V 4100 - RESILIENT 4 GALLON ADHESIVE (ROLLS) RESILIENT EA 261.85$ 51% 129.12$ None No S103V 4100‐4G ADHESIVE RESILIENT EA 261.85$ 51% 129.12$ None No 341VS 4151 PRESSURE SENSITIVE UNIVERSAL ADHESIVE RESILIENT EA 214.94$ 25% 161.87$ None No 9150D 4151 PRESSURE SENSITIVE UNIVERSAL ADHESIVE BROADLOOM EA 214.94$ 25% 161.87$ None No 9150V 4151 PRESSURE SENSITIVE UNIVERSAL ADHESIVE BROADLOOM EA 214.94$ 25% 161.87$ None No LWRX2 LOKWORX BOX TILE EA 213.96$ 24% 163.42$ None No I0446 CUSHIONWORX 2MM TILE Roll 231.00$ 23% 178.71$ None No 9000D BARRIER COAT ‐‐ FLOOR ENCAPSULATION BROADLOOM Pail 236.37$ 24% 179.65$ None No 900DU 9000 - BARRIER COAT UNITS TILE Pail 236.37$ 24% 179.65$ None No 03LDR LOKDOKS TILE EA 375.00$ 46% 202.80$ None No AVDES ADHESIVE ALTERNATIVE -- SHAW ADVANTAGE SYSTEM BROADLOOM Roll 409.08$ 24% 311.55$ None No
AVDEU ADHESIVE ALTERNATIVE -- SHAW ADVANTAGE SYSTEM
UNITS
TILE Roll 409.08$ 24% 311.55$ None No I0432 CUSHIONWORX 3MM TILE Roll 386.56$ 13% 334.96$ None No S112V VS‐60 VERSASHIELD 60 RESILIENT EA 897.50$ 32% 607.90$ None No 9125D MOISTURETEK BROADLOOM EA 887.18$ 22% 695.11$ None No 9125P MOISTURETEK RESILIENT EA 887.18$ 22% 695.11$ None No 9125V MOISTURETEK TILE EA 887.18$ 22% 695.11$ None No S113V VS‐60 MBX VERSASHIELD 60 RESILIENT EA 2,556.25$ 34% 1,688.66$ None No US Floors (Patcraft)
I423V EMERY RESILIENT SF 6.86$ 58% 2.87$ PVC Content YES, ISO14025 Industry Average EPD
S202V OVERLAP REDUCER EMERY RESILIENT EA 45.50$ 37% 28.56$ PVC Content No S204V QUARTER ROUND EMERY RESILIENT EA 45.50$ 37% 28.68$ PVC Content No S203V T-MOLDING EMERY RESILIENT EA 45.50$ 37% 28.78$ PVC Content No S200V BABY THRESHOLD EMERY RESILIENT EA 45.50$ 37% 28.87$ PVC Content No S201V FLUSH STAIRNOSE EMERY RESILIENT EA 54.25$ 35% 35.14$ PVC Content No The products above marked with an * are solution dyed, however, they are not 100% solution dyed. We believe these products will perform according to your requirements.
Broadloom products listed above do not meet UCOP's recycled content requirements.
Pricing above is effective from October 1, 2019 - September 30, 2020.
ACH Net 60
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F SUPPLIER:
Labor Description UOM Standard Rates
Installation Carpet Tile SqYD 8.47
Removal of Carpet Tile SqYD 3.85
Installation Broadloom (direct glue down) SqYD 9.63
Installation Broadloom (w/Pattern) SqYD 10.63
Removal of Broadloom (direct glue down) SqYD 3.85
Removal of Double Stick Installation SqYD 3.85
Removal/Disposal Resilient Flooring SqFt 1.29
Carpet Disposal SqYD 1.21
Carpet Reclamation Fee (Shaw Ecoworx tile no cost) SqYD 2.5 Installation of VCT (No Pattern, excludes materials) SqFt 1.49 Installation of Luxury Vinyl Tile (No pattern, excludes materials) SqFt 3.2
Installation of Rubber (Tile or Roll) SqFt 2.74
Installation of Sheet Vinyl (No Weld; Cove; Pattern; Excludes Materials) SqYD 29.27
Heat Welding (Sheet Vinyl) Linear FT 6.22
Installation Flash Cove (Sheet Vinyl) Linear FT 4.75
Palletize/Shrink Wrap Old Carpet for Reclamation SqYD 2.1 Conventional Furniture Moving (Light) Hourly Labor Rate 71.5 Conventional Furniture Moving Medium) Hourly Labor Rate 78.65 L I F T Systems / Carpet Tile Projects Only SqYD 25.3
Moisture Testing EACH 200
Furnish/Install Resilient 4" Base Linear FT 3.71
Furnish/Install Resilient 6" Base Linear FT 3.71
Furnish/Install Carpeted 4" Base Linear FT 3.55
Furnish/Install Carpeted 6" Base Linear FT 3.55
Furnish/Install Transition Linear FT 6.95
Tile Laying & Installation SqFt 1.1
Floor Prep - Skim Coating to 1/8 inch (Material & Labor) SqFt 1.05 Floor Prep Self leveling to 1/4 inch (Material & Labor) SqFt 1.05 Hourly Rate for Services Not Listed Hourly Labor Rate 95 Project Management Fees (up to 20% of material cost) < = 20% Installation ADD ON - Night/Weekend SqYD 4.75
Installation ADD ON - Sunday SqYD 7.15
Supplemental Benefit
HR < = $25.00
NorCal (Area 1 - UCB,UCSF)
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F Prevailing Wage Standard Rates Prevailing Wage Standard Rates Prevailing Wage
11.26 8.47 11.26 8.47 11.26
5.72 3.85 5.72 3.85 5.72
12.65 9.63 12.65 9.63 12.65
13.65 10.63 13.65 10.63 13.65
5.72 3.85 5.72 3.85 5.72
5.72 3.85 5.72 3.85 5.72
3.75 1.29 3.75 1.29 3.75
2.55 1.21 2.55 1.21 2.55
2.5 2.5 2.5 2.5 2.5
2.88 1.49 2.88 1.49 2.88
4.94 3.2 4.94 3.2 4.94
3.68 2.74 3.68 2.74 3.68
36.22 29.27 36.22 29.27 36.22
8.4 6.22 8.4 6.22 8.4
6.38 4.75 6.38 4.75 6.38
2.84 2.1 2.84 2.1 2.84
86.9 71.5 86.9 71.5 86.9
95.59 78.65 95.59 78.65 95.59
33 25.3 33 25.3 33
275 200 275 200 275
5.01 3.71 5.01 3.71 5.01
5.01 3.71 5.01 3.71 5.01
4.79 3.55 4.79 3.55 4.79
4.79 3.55 4.79 3.55 4.79
9.38 6.95 9.38 6.95 9.38
1.49 1.1 1.49 1.1 1.49
2.36 1.05 2.36 1.05 2.36
2.36 1.05 2.36 1.05 2.36
125 95 125 95 125
< = 20% < = 20% < = 20% < = 20% < = 20%
5.94 4.75 5.94 4.75 5.94
8.94 7.15 8.94 7.15 8.94
< = $25.00 < = $25.00 < = $25.00 < = $25.00 < = $25.00
NorCal (Area 1 - UCB,UCSF) NorCal (Area 2 - UCSC) NorCal (Area 3 - UCD) DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F Standard Rates Prevailing Wage Standard Rates Prevailing Wage Standard Rates
8.47 11.26 8.47 11.26 8.47
3.85 5.72 3.85 5.72 3.85
9.63 12.65 9.63 12.65 9.63
10.63 13.65 10.63 13.65 10.63
3.85 5.72 3.85 5.72 3.85
3.85 5.72 3.85 5.72 3.85
1.29 3.75 1.29 3.75 1.29
1.21 2.55 1.21 2.55 1.21
2.5 2.5 2.5 2.5 2.5
1.49 2.88 1.49 2.88 1.49
3.2 4.94 3.2 4.94 3.2
2.74 3.68 2.74 3.68 2.74
29.27 36.22 29.27 36.22 29.27
6.22 8.4 6.22 8.4 6.22
4.75 6.38 4.75 6.38 4.75
2.1 2.84 2.1 2.84 2.1
71.5 86.9 71.5 86.9 71.5
78.65 95.59 78.65 95.59 78.65
25.3 33 25.3 33 25.3
200 275 200 275 200
3.71 5.01 3.71 5.01 3.71
3.71 5.01 3.71 5.01 3.71
3.55 4.79 3.55 4.79 3.55
3.55 4.79 3.55 4.79 3.55
6.95 9.38 6.95 9.38 6.95
1.1 1.49 1.1 1.49 1.1
1.05 2.36 1.05 2.36 1.05
1.05 2.36 1.05 2.36 1.05
95 125 95 125 95
< = 20% < = 20% < = 20% < = 20% < = 20%
4.75 5.94 4.75 5.94 4.75
7.15 8.94 7.15 8.94 7.15
< = $25.00 < = $25.00 < = $25.00 < = $25.00 < = $25.00
San Diego - UCSDNorCal (Area 4 - UCM) SoCal (Area 1 - UCLA, UCI, UCR, UCSB) DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F Prevailing Wage
11.26 5.72
12.65 13.65
5.72 5.72
3.75 2.55
2.5 2.88
4.94 3.68
36.22 8.4
6.38 2.84
86.9 95.59
33 275
5.01 5.01
4.79 4.79
9.38 1.49
2.36 2.36
125
< = 20%
5.94 8.94
< = $25.00
San Diego - UCSD
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F SUPPLIER:
New York Region 1:
Bronx, Queens, Kings,
Richmond, Nassau,
Suffolk, Putnam,
Westchester & Orange
Counties
New York Region 2:
Erie, Niagara, St.
Lawrence, Franklin,
Essex, Jefferson, Lewis,
& Hamilton Counties
**Labor Description Labor Rate Labor Rate
Monday - Friday Standard 8 Hour Shift $140.74 $140.73
Monday - Friday Overtime $182.96 $182.95
Saturday $182.96 $182.95
Sunday & Holiday $229.87 $229.87
***ALL RATES PROVIDED ABOVE FOR FOR BUDGETARY PURPOSES ONLY***
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F New York Region 3:
Remainder of State of
New York
Labor Rate Non Union Rate Union Wage Rate Non Union Rate Union Wage Rate $140.73 $85.79 $126.60 $66.00 $97.40
$182.95 $111.52 $164.57 $85.80 $126.62
$182.95 $111.52 $164.57 $85.80 $126.62
$229.87 $140.12 $206.77 $107.80 $159.08
Southeast Region:
AL, FL, GA, KY, NC, SC,
Northeast Region:
MA, ME, VT, NH, CT, RI, PA, VA, DC, RI,
MD, DE, NJ
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F Non Union Rate Union Wage Rate Non Union Rate Union Wage Rate Non Union Rate $66.00 $97.40 $77.00 $122.10 $77.00
$85.80 $126.62 $96.80 $155.10 $96.80
$85.80 $126.62 $96.80 $155.10 $96.80
$107.80 $159.08 $116.60 $188.10 $116.60
West
CA, CO, HI, AK, NV, NM, OR, WA, WY,
MT, ID, SD, ND, UT
South:
AR, AZ, TX, LA, MS
Central:
KS, OH, MI, MN, WI, MO, OK, MS, NE,
IA, PA, IL, IN
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F Union Wage Rate Non Union Rate Union Wage Rate
$113.44 $77.00 $113.44
$142.61 $96.80 $142.61
$142.61 $96.80 $142.61
$171.78 $116.60 $171.78
Non-Continental:
AK & HI
West
CA, CO, HI, AK, NV, NM, OR, WA, WY,
MT, ID, SD, ND, UT
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F University of California Agreement 2020002144 – Shaw Industries, Inc.
Attachment C – Reporting Requirements
Supplier must provide electronic reports (in Microsoft Excel) to designated UC contacts providing a wide range of information, at both the system-wide and campus level, related to the Agreement including, but not limited to:
Recycling & Reclamation
On a quarterly basis, Supplier will report recycling and reclamation efforts on supplier lead projects throughout the system.
It is required that 100% of existing carpet including carpet padding be taken to a recycling facility that accepts carpet for recycling unless otherwise required by law. Recycling means turning any manufacturer’s old carpet or carpet components into new carpet or other consumer products.
Any exception to the recycling requirement will be communicated to the campus project contact and captured in Recycling & Reclamation reporting.
Supplier will format quarterly report in the following manner:
Column Title Description Column Mapping
UC Campus Site of Work A
Project Description Building/Location B
Project Purchase Order Project PO Number C
Type of Material Carpet | LVT | Rubber | Linoleum | Etc. D Amount of Material Sq Ft/Yd captured E
Reclamation Method Recycled|Incinerated|Other F
Final Disposal Site Company/Location of Final Disposition G Cost of Reclamation Invoiced Amount for Service H
Certificate of Disposal Provided Yes (Y) or No (N) – Certificate Number I
Small Business Utilization
On a quarterly basis, Supplier will report Small Business utilization on all Supplier lead projects.
In support of University of California Sustainable Practices guidelines that aim to reach 25% Economically and Socially Responsible Spend as a total percentage of addressable spend, supplier will make best effort to achieve 50% utilization of SBA designated subcontractors to perform services across the University of California system.
Supplier will format quarterly reporting in the following manner:
Column Title Description Column Mapping
UC Campus Site of Work A
Project Description Building/Location B
Project Purchase Order Project PO Number C
Subcontractor Name of Subcontractor Business E
Subcontractor’s SBA Designation Certified SBA Class F
Total Invoice Amount for Services All Labor Billing Performed by SBA G DIR Project ID DIR Project Number H
University of California Sales Reporting
Monthly, Supplier will provide full reporting of all sales captured under this agreement. Supplier will repor t sales made directly to the University, as well as any University sales reported through Supplier’s distribution network.
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F University of California Agreement 2020002144 – Shaw Industries, Inc.
Supplier will provide monthly sales reporting in the following format:
Column Title Description Column Mapping
UC Campus Site of Work A
Project Description Building/Location B
Project Purchase Order Project PO Number C
Category Product | Service | Freight | Reclamation E
Line Item Detail SKU | Style | Labor Category F
Total Invoice Amount for Line F Total Amount Billed in USD ($) G Billing Date DD/MM/YY H
Carbon Neutral Incentives
In the initial 24-months of the Agreement, any of Supplier’s EcoWorx brand carpet tile Goods sold for use in University facilities will be carbon neutral. Supplier shall purchase carbon offsets equivalent to $.10/sqyd for any University purchase of EcoWorx brand carpet tiles. Any such EcoWorx Good order must be placed wi th Supplier’s Shaw Intregrated Solutions group and reference this agreement. Thereafter, the parties will assess and evaluate an extension of the Carbon Neutral Incentive during the Term, in whole or part. This carbon neutral incentive shall be available only to University facilities, the parties hereby agree this incentive will not apply to the National Intergovernmental Purchasing Alliance Company, a Delaware corporation d/b/a OMNIA Partners Public Sector (“Omnia”), under any Omnia contract, to any other Omnia member, or to any Good ordered place thereby.
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F UCOP Agreement # 2020002144 – Shaw Industries Page 1 of 6
This Electronic Commerce Appendix specifies the electronic commerce requirements applicable to Supplier in providing the Goods and/or Services.
SECTION 1 - GENERAL TERMS
Each UC Location offers an electronic web-based purchasing and catalog system to facilitate the purchase of Goods and/or Services from UC suppliers. UC Locations’ eProcurement systems currently are provided by multiple service providers. Eight of the ten UC campuses utilize the same platform but may require separate implementations, as will the remaining campuses and/or Medical Centers. This Appendix sets forth the terms and conditions that will govern Supplier’s sale of Goods and/or Services through UC’s eProcurement systems.
SECTION 2 - DEFINITIONS
Catalog(s) refers to the list of detailed product information, agreement pricing, manufacturer part numbers and/or service descriptions relating to the Goods and/or Services to be offered either as a Punch-out Catalog, a Hosted Catalog or in a combination. This may include the creation of multiple Hosted Catalogs.
eProcurement and eCommerce are used interchangeably to mean UC’s electronic web -based purchasing and catalog systems. Each UC location has a branded eProcurement site.
Go Live Date means the date on which a Catalog will be active.
Hosted Catalog means a Catalog that is a properly formatted computer file supplied to all UC Locations through the Locations’ respective eProcurement systems.
Order means a purchase order for Goods and/or Services placed by a User through an eProcurement system.
Order Data means all data and information relating to Orders, including, without limitation, the specifics of a given transaction.
Punch-out Catalog means a Catalog hosted by Supplier on Supplier’s Site. Users may access this Punch-out Catalog via an Internet link provided by Supplier to UC that redirects a User from the Location’s eProcurement system to Supplier Site.
Supplier Mark means Supplier’s name, trade name and/or trademarks, service mark, or any derivation thereof.
Supplier Site means an internet site operated and maintained by Supplier that has been made subject to this Appendix.
UC Mark means UC’s name, trade name and/or trademarks, service marks, or any derivation thereof.
User means an individual authorized by a UC location to use an eProcurement system.
SECTION 3 – RIGHT TO USE
UC grants to Supplier the right to sell Goods and/or Services to UC through the eProcurement systems, subject to the terms of this agreement. Supplier will be responsible for any cost of operation or dispute with regard to its interface with UC’s eProcurement systems.
Appendix- Electronic Commerce
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F UCOP Agreement # 2020002144 – Shaw Industries Page 2 of 6
SECTION 4 – e-PROCUREMENT SYSTEM RESPONSIBILITIES; MAINTENANCE OF CATALOG(S); LICENSE
(a) e-Procurement System Responsibilities.
Except as otherwise set forth herein, each party will be responsible, at its own expense, for: (i) developing, operating and maintaining its relevant system(s); (ii) acquiring and maintaining its server hardware and software (or obtaining third-party hosting services) for its relevant system(s); and (iii) maintaining Internet connectivity.
The supplier will enable its catalog with any UC location that requests one, as long as it is not out of the scope of the terms of the agreement or this appendix. The parties agree to electronically link the functionality of their respective systems, using commercially reasonable efforts.
Purchase Order and Invoice/Credit Memo Data will be transmitted between the systems according to the appropriate method for each University location, cXML, xCBL or EDI standards being preferred. Other methods of PO or Invoice/Credit Memo transmission will only be allowed at the discretion of each University location.
A supplier’s Punch-out site (if applicable) will permit: (a) Users to access the Supplier Site when a User selects the Punch-out Catalog; (b) Supplier site to send back user selected items to Location’s eProcurement system; (c) User to create an Order through the Location’s eProcurement system; and (d) UC eProcu rement systems to forward an Order to Supplier for confirmation and Order processing along with Order status inquiry.
Supplier must be able to accommodate orders and invoices for multiple UC locations sharing a single eProcurement platform. Supplier must be able to identify the Punch-out session and transmitted PO as being from the individual locations. If providing a Punch-out catalog, Supplier must be able to accommodate multiple UC locations on a single platform using a single Punch-out site, unless requested otherwise by UC.
(b) Maintenance of Hosted and Punch-out Catalogs.
Supplier will provide its Catalog(s) to UC in a file format that will interface seamlessly with UC’s eProcurement systems. These Catalog files will be in compliance with each UC Location’s eProcurement system.
UC makes no guarantee of a Go Live Schedule for establishment of a new catalog Systemwide, as each Location is a separate enablement and subject to resource availability. Timelines will be estimated and adjusted by UC as needed for concurrent implementations.
For Hosted Catalogs, Supplier must provide UC with updated versions of the Catalog file with, at a minimum, full descriptions and images that Supplier currently utilizes for items offered in its proprietary websites and P unch-out Catalogs. The parties will update each other regarding eCommerce specifications as needed from time to time.
Supplier must notify UC’s Contract Administrator at least three (3) weeks in advance of the proposed Go Live Date if it will be requesting additions, deletions, or modifications to the Catalogs. After such advance notification, Supplier must provide UC with Catalog files containing the requested additions, deletions, or modifications with no less than the lead time specified in Section 10 of this appendix. In addition, for price file updates with a mutually agreed upon activation of January 1, Supplier must submit proposed files at least five (5) weeks prior to the first working day in January. Upon UC’s approval of the new Catalog file, UC and Supplier will confirm the Go Live Date; the updated version of the Catalog file will be made effective on that Go Live date. If UC rejects a Catalog more than once because it does not meet UC’s acceptance criteria, the Contract Administrator will suspend Supplier’s price/content change until the date of Supplier’s next acceptable contracted change.
If there is a conflict betwee n a price in a Hosted Catalog and a Punch-out Catalog, UC will be invoiced at the lower price. Supplier must notify UC in advance when substituting items, changing SKU numbers or changing the number of items in a package in any Catalog.
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F UCOP Agreement # 2020002144 – Shaw Industries Page 3 of 6
Content in Supplier catalog is limited to the categories specified in this agreement, with additional categories allowed at UC’s discretion. Supplier agrees that UC may block Catalog items at the category and/or SKU level.
The University will require Supplier to clearly identify products as Hazardous Materials, Radioactive, and Controlled Substances in the Supplier’s catalog, whether Hosted or Punch-out. For Punch-out the identifier will be returned to the cart of the Location’s eProcurement system, in a manner/field acceptable to the Location.
The University will require Supplier to clearly identify products with UC-recognized sustainability/green certifications in both hosted and Punch-out catalogs. UC’s Contract Administrator will work with Supplier to ensure that contract items that meet the UC criteria for Green /Sustainable products will be prioritized in all product searches. Products that do not meet UC’s minimum criteria requirements may be blocked in all hosted catalogs and Punch-out catalogs at UC’s discretion.
Supplier is responsible for providing UC with Catalogs that contain accurate pricing and data in accordance with the Agreement. If UC determines there are errors in the pricing or data attributes of a Catalog, UC will notify Supplier of those errors in writing and reject the Catalog. Supplier will have no more than ten (10) business days to review and correct the errors.
(c) License.
Supplier hereby grants to UC, at no additional cost, a limited, non-exclusive, royalty-free right to link to and access the Supplier Site from the eProcurement sites, subject to the terms and conditions herein and solely for the purpose of permitting Users to access the Services. All Supplier Marks will remain the sole property of Supplier.
(d) Accessibility Requirements.
Supplier agrees that Supplier will make available Goods/Services accessible to people with disabilities and conform to the technical requirements of the relevant Revised Standards of Section 508 of the federal Rehabilitation Act. In addition, Supplier warrants that:
i. Any catalog content provided to UC will comply with the accessibility requirements of WCAG 2.0AA. ii. Supplier will promptly respond to and resolve any complaint regarding acce ssibility of any catalog content provided to UC.
SECTION 5 – USER SUPPORT
(a) UC Duties. Each UC Location will provide its Users with initial contact and system support assistance on all functionality and use issues for eProcurement (including links to the Supplier Site). When known, UC will promptly notify Supplier of any such issues relating to the Catalog, the Supplier Site, and/or other Supplier materials/systems.
(b) Supplier Duties. Supplier will provide all customer support relating to the Catalog, Supplier Goods and/or Services, Invoicing/Payment/Credits, and Supplier Sites in a manner consistent with the customer support that Supplier provides to other customers, and at least as good as the customer support that Supplier provides to customers who are purchasing through any other means.
SECTION 6 – PROPRIETARY RIGHTS
UC’s Terms and Conditions of Purchase contains provisions regarding the parties’ rights and responsibilities with respect to intellectual property relating to the Goods and Services . Without altering those provisions, the parties additionally agree as follows: UC may require Supplier to “brand” Supplier’s Punch-out Catalog with one or more UC Marks. If UC requires Supplier to utilize one or more UC Marks on Supplier’s Punch-out Catalog, UC will provide the appropriate artwork and such artwork will be deemed to have been provided with a limited, non-exclusive, non-sub- DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F UCOP Agreement # 2020002144 – Shaw Industries Page 4 of 6
licensable right for Supplier to use it solely for the purpose of a UC -branded Punch-out Catalog hosted by Supplier and subject to the following terms:
(i) Supplier may not make any additional use of the UC Marks without UC’s prior written approval.
Supplier’s use of the UC Marks in the Punch-out Catalog must acknowledge UC's ownership of the UC Marks. Supplier will include all notices and legends with respect to UC trademarks, trade names, or copyrights as may be required by applicable trademark and copyright laws or which may be reasonably requested by UC . Supplier agrees not to claim any title to UC Marks or any right to use UC Marks except as permitted by this Appendix. Upon termination of this Appendix or the Agreement , all rights to UC Marks conveyed by UC to Supplier will cease and Supplier will destroy or return to UC all media with UC Marks . UC specifically reserves any and all right s to UC Marks not specifically granted to Supplier.
Supplier grants to UC the right to use Supplier's trademarks, logos, trade names, and service marks for the purpose of promoting UC eProcurement sites to the UC community. UC acknowledges Supplier's right, title, and interest in and to Supplier’s Marks and Supplier’s exclusive right to use and license the use of Supplier Marks and agrees not to claim any title to Supplier Marks or any right to use Supplier Marks except as p ermitted by this Appendix. UC will include all notices and legends with respect to Supplier trademarks, trade names, or copyrights as may be required by applicable trademark and copyright laws or which may be reasonably requested by Supplier. Upon termination of this Appendix, all rights to Supplier Marks conveyed by Supplier to UC will cease and UC will destroy or return to Supplier all media with Supplier Marks . Supplier specifically reserves any and all right to Supplier Marks not specifically granted to UC.
(ii) The licenses granted in the previous paragraphs regarding UC Marks and Supplier Marks are subject to the ongoing approval of the party owning the respective trademarks, logos, trade names, or copyrights.
Such ongoing approval includes the ability to terminate – at any time, for any reason, and in the sole discretion of the owner of the respective trademarks, logos, trade names, or copyrights – the trademark licenses provided in the preceding paragraphs for any particular trademark, logo, trade name, or copyrighted work without necessarily terminating this Appendix. Each party agrees not to take any action that will adversely reflect upon or damage the goodwill, reputation, or the brand value of the other party. Each party further agrees not to take any action that is inconsistent with the other party’s ow nership of the respective trademarks, trade names, or copyrights . At all times (including following termination of the Agreement), Supplier agrees to comply with Section 92000 of California’s Education Code.
(a) Grant of License. Supplier hereby grants UC a non-exclusive, royalty-free: (i) license to use, copy , transmit, and display the Catalog, any information contained therein and the Supplier Marks for the purposes of permitting Customers to access information about and order Supplier Goods and/or Services from a Catalog and (ii) if Supplier is using a Punch-out Catalog, right to link to and access the Punch-out Catalog on the Supplier Site, for the purposes of permitting Customers to access the Supplier Website and permitting Customers to order Supplier Goods and/or Services.
(b) Modifications. UC will not modify or remove any of the proprietary rights markings in the Catalog. UC will not modify the content of the Catalog, except as indicated by Supplier, but may require Supplier to make and submit modifications if required as part of this agreement . However, for hosted catalogs, UC reserves the right to attach flags to catalog items as an aid to shoppers in selecting preferred items, such as green or recycled. UC will not make any representations or warranties, or provide any information, to any third party regarding any Supplier Goods and/or Services (including, but not limited to, any representations or warranties of any information regarding availability, delivery, pricing, characteristics, qualifications or specifications thereof). If UC believes in good faith that any Supplier information does not conform to the requirements of the associated UC Agreement or this Appendix, UC will be entitled to withdraw the Catalog from UC eProcurement sites. In such a case, UC will promptly notify the Supplier of the actions it has taken and will work with the Supplier promptly to resolve UC’s concerns. When UC’s DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F UCOP Agreement # 2020002144 – Shaw Industries Page 5 of 6
concerns are satisfactorily resolved UC will promptly restore the Catalog, if appropriate. UC will have no liability to the Supplier or anyone else for exercising these rights.
(c) Acknowledgment. Each party acknowledges that the technology embodied in the other party’s Site may be based on patented or patentable inventions, trade secrets, copyrights or other intellectual property or proprietary rights (“Intellectual Property Rights”) owned by the other party and its applicable licensors.
(d) UC Rights. As between the parties, UC will be the sole owner of – or, with respect to any items licensed by UC, will retain all rights to all Intellectual Pro perty Rights associated with UC eProcurement sites, including any modifications, updates, enhancements or upgrades to any of the foregoing, as well as any Order Data generated or collected on such site (collectively, the “UC Materials”). Except as provided herein, Supplier may not copy or use in any way, in whole or in part, any UC Materials without UC’s prior written approval. Any permitted copies of such property, in whole or in part, alone or as part of a derivative work, will remain UC’s sole property. Supplier agrees to reproduce and include UC’s copyright, trademark and other proprietary rights notices on any permitted copies of UC Materials including, without limitation, partial copies and copied materials in derivative works. Supplier will not copy or reproduce any third -party copyrighted or tradema rked materials, which appear on or are otherwise associated with any UC eProcurement site without UC’s prior written consent.
SECTION 7 – MULTIPLE SUPPLIERS
Supplier acknowledges that all UC eProcurement sites are intended to facilitate Users’ ability to obtain Goods and/or Services from more than one supplier. Nothing in this Appendix will be construed to prevent UC from entering into similar agreements with any third parties including, without limitation, suppliers that may be in competition with Supplier.
SECTION 8 – WARRANTY DISCLAIMER
UC does not warrant that access to UC eProcurement sites will be uninterrupted or that the results obtained by use of UC eProcurement sites will be error-free.
SECTION 9 – DISPUTES AND CHANGES IN THE SERVICES
(a) UC and Supplier agree to negotiate in good faith to resolve problems, questions and disputes.
(b) Where improvements and clarifications can be made in the business processes related to eProcurement, both parties agree to incorporate such changes as long as they are mutually agreed upon.
SECTION 10 – ADDITIONAL CONTRACTUAL TERMS
In addition to the provisions of Section 4, Section 10 provisions will govern the Catalogs. If the provisions of Sections 4 and 10 conflict, Section 10 will govern.
Type(s) of Catalog(s): At UC’s campus discretion, Supplier is allowed to implement a Hosted or Punch-out catalog in the UC eProcurement systems. Supplier will be required to comply with UC Location e -commerce requirements on a location by location basis, which includes the decision to move forward with Punch -out or Hosted. Any deviation from the type(s) specified herein must first be agreed upon by UC’s Contract Administrator.
Annual Number of Catalogs: Supplier is allowed to submit no more than 1 catalogs per calendar year, with changes as follows:
Content Additions, Deletions and Other Non-pricing Edits: Bi-annually Price Changes: Annually
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F UCOP Agreement # 2020002144 – Shaw Industries Page 6 of 6
o Allowable level of price change ($/%) will be in accordance with the terms of this agreement. o If a price file includes both content and pricing changes, it will count toward the pricing allocation.
Lead time: Supplier must load the Catalog price file into the e-Procurement system 10 working days prior to the planned go-live date. (Exception – for January 1 updates to enabled catalogs, Supplier must submit the price file no later than 5 weeks prior, as specified in section 4.)
Number of catalog/price file versions to be supported for this agreement: 1 Categories allowed within Catalog: all products meeting University of California specifications Categories blocked within Catalog: all products that fall below University of California specifications
DocuSign Envelope ID: 5C868B9D-8228-4A7E-97D3-0D74A5B2A47F
Formal Bidding (Section 2611])
Written Contract (Section 2605(1)(iii))
Pursuant to CMC Section 2611:
(d) Emergency Purchasing (Section 2611(d))
(e) Sole Source Purchasing (Section 2611(e))
(f) Piggyback Purchasing (Section 2611(f))
(g) Cooperative Purchasing (Section 2611(g))
(i) Other Purchases (Section 2611(i)(1) through (18))
If (f) or (g) are selected above, specify the master contract details:
Vendor:
Solicitation #:
Contract Expiration:
Authorized Department Staff: Purchasing:
Purchasing Division
701 E. Carson Street
Carson, CA 90745
Purchasing Waiver
Use this form to request an exemption from formal bidding and/or written contract requirements, pursuant to Chapter 6 (Purchasing System) of Article II (Administration) of the Carson Municipal Code (CMC). This waiver must be completed before proceeding with procurement activity.
Exemption sought:
Name/Title:
Date:
Signature:
Awarding Agency:
Contract #:
Contract Effective Date:
Written justification/description of purchase. Explain urgency, product uniqueness, and intended use. Attach all relevant backup documentation.
Amount: Vendor:
Specify purchase details:
Rev. 0825JT
Solitude
Packaging
Collection Solitude
Style Number 0648V
Construction Heavy Commercial Luxury Vinyl Tile With
Fiberglass
Class / ASTM F1700 Class III, Type B
Finish ExoGuard®
U.S. Metric
Nominal Dimensions 6 in w x 48 in l 15 cm w x 122 cm l
Actual Dimensions 6.00 in w x 48.00 in l 15.24 cm w x 121.92 cm l Wear Layer Thickness 20 mil (0.02 in) 0.51 mm
Overall Thickness 0.197 in 5 mm
Edge Profile Squared Edge
Installation Type Dry Back
Installation Direct Glue
Recommended
Adhesive
2200 1 Gallon, 2200 4 Gallon, 4151, 4200 1 Gallon,
4200 4 Gallon, 4252 (No Heavy Rolling or Static
Loads) or S150-95
Pieces per Carton 10 pcs
Area per Carton 20 sq ft 1.86 sq m
Weight per Carton 35.1 lbs 15.92 kg
Recommended Installation Method
Brick
Ashlar
Herringbone
Stagger
Performance + Testing
Test Reports may be included or listed by the manufacturing/inventory style number as opposed to the noted selling style number.
Static Load (ASTM F970) Passes (Modified), *1500 lbs
Residual Indentation (ASTM F1914) Passes
Resistance to Heat (ASTM F1514) Passes
Resistance to Light (ASTM F1515) Passes
Resistance to Chemicals (ASTM F925) Passes
Smoke Density (ASTM E662, Flaming Mode) Passes
Radiant Panel (ASTM E648) Passes, Class I
Coefficient of Friction (ASTM D2047, Slip
Resistance)
>0.6, meets the recommended static coefficient of friction for ADA walking surfaces and accessible routes
*This test is intended to compare relative properties of different styles and constructions. Results are based on a laboratory test and used for comparative purposes - real life load limit may vary.
Corporate Headquarters +1 800 257 7429 | +1 706 532 7984 | Atlanta +1 404 853 7429 | Bengaluru +91 80 6773 0202 | Beijing +86 10 6568 588 | Chicago +1 312 467 1331 | Dubai +971 4 584 6956 | Hong Kong +852 2623 0371 | London +44 207 961 4120 | Los Angeles +1 800 233 1614 | Melbourne +61 3 9939 8543 | Mexico City +55 5010 7600 | Mumbai +91 22 6284 5050 | Nantong +86 400 800 7429 | New York +1 212 953 7429 | Paris +33 (0) 1 81 22 44 39 | San Francisco +1 415 955 1920 | Shanghai +86 21 3338 4000 | Singapore +65 6733 1811 | Sydney +61 800 556 302 © 2026 Shaw Industries Group, Inc., a Berkshire Hathaway Company March 19, 2026
1 of 3
For reference purposes only if printed or downloaded.
Solitude
Warranties
Diversity & Inclusion
We promote supplier participation that is reflective of Shaw Industries' diverse customer base and local community. We believe having a strong Supplier Diversity Program is strategic for bringing more innovation to our businesses and opening new markets for growth.
Material Health & Environmental Certifications
Health & Wellbeing
Climate Impact
Works With WELL | WELL V2 Contribution Credit
15 Year Commercial Limited Warranty
Commercial Limited Underbed Bond Warranty
Material & Ingredient Transparency Health Product Declaration (HPD) | 1000 ppm Disclosure Indoor Air Quality FloorScore® | Certified
Environmental Product Declaration (EPD) 3rd Party Certified in Accordance with ISO 14025, EN 15804, & ISO 21930:2017
Embodied Carbon (Cradle to Gate) 11.59 Kg Co ₂ /M²
Total Recycled Content 0% (Pre-Consumer 0% | Post-Consumer 0%) Global Product Assessment GSA | Approved
CE Marking (EN 14041) | 3rd Party Certified
Country of Origin | Imported
X01 Fundamental Material Precautions
Part 1: (C): Restrict Asbestos Precondition
Absence of Asbestos
X08 Hazardous Material Reduction
Part 1: Limit Hazardous Materials Optimization
Absence of Heavy Metals
X10 Volatile Compound Reduction
Part 1 (A): Manage Volatile Organic Compounds (VOCs) Optimization Absence of Halogenated Flame Retardants
X10 Volatile Compound Reduction
Part 2: Manage Semi-Volatile Organic Compounds (SVOCs) Optimization Ortho-Phthalates
X11 Long Term Emissions Control
Part 2: Flooring Optimization
FloorScore Certified
X14 Material Transparency
Part 1: Promote Ingredient Disclosure Optimization
Health Product Declaration (HPD) | 1000 Ppm Disclosure
Corporate Headquarters +1 800 257 7429 | +1 706 532 7984 | Atlanta +1 404 853 7429 | Bengaluru +91 80 6773 0202 | Beijing +86 10 6568 588 | Chicago +1 312 467 1331 | Dubai +971 4 584 6956 | Hong Kong +852 2623 0371 | London +44 207 961 4120 | Los Angeles +1 800 233 1614 | Melbourne +61 3 9939 8543 | Mexico City +55 5010 7600 | Mumbai +91 22 6284 5050 | Nantong +86 400 800 7429 | New York +1 212 953 7429 | Paris +33 (0) 1 81 22 44 39 | San Francisco +1 415 955 1920 | Shanghai +86 21 3338 4000 | Singapore +65 6733 1811 | Sydney +61 800 556 302 © 2026 Shaw Industries Group, Inc., a Berkshire Hathaway Company March 19, 2026
2 of 3
For reference purposes only if printed or downloaded.
Solitude
Leed v4 Contribution Credits
Available Colorways
Cocoa 48103
LRV 20.8 | L* 52.74
V2 - Slight Variation
Cottonwood 48120
LRV 42.5 | L* 71.25
V2 - Slight Variation
Natural 48250
LRV 28.7 | L* 60.55
V2 - Slight Variation
Smoke 48506
LRV 26.3 | L* 58.3
V2 - Slight Variation
Fawn 48516
LRV 25.7 | L* 57.74
V2 - Slight Variation
Urban Ash 48540
V2 - Slight Variation
Char 48549
LRV 7.2 | L* 32.3
V2 - Slight Variation
Pewter 48595
LRV 22.6 | L* 54.67
V2 - Slight Variation
French Grey 48599
LRV 20.8 | L* 52.69
V3 - Moderate Variation
Mink 48720
LRV 16.8 | L* 47.99
V3 - Moderate Variation
Woodland 48760
LRV 17.2 | L* 48.51
V2 - Slight Variation
Umber 48761
LRV 11 | L* 39.65
V2 - Slight Variation
MR Credit: Building Product Disclosure and Optimization Material Ingredients - Option 1: Material Ingredient Reporting Health Product Declaration (HPD) | 1000 Ppm Disclosure
MR Credit: Building Product Disclosure and Optimization Environmental Product Declarations - Option 1: Environmental Product Declaration (EPD) 3rd Party Certified in Accordance with ISO 14025, EN
15804, & ISO 21930:2017
EQ Credit: Low Emitting Materials
Option 1: Product Category Calculations
FloorScore Certified
Installation Guidelines
Maintenance Guidelines
Please visit www.shawcontract.com for the most current warranty information.
Specifications are subject to nominal manufacturing variance. Material supply and/or manufacturing processes may necessitate changes without notice.
This product is an exclusive design and may not be duplicated in any manner. Use of this design in the creation of another product design is also strictly prohibited.
Visit shawcontract.com/testing for more information.
Corporate Headquarters +1 800 257 7429 | +1 706 532 7984 | Atlanta +1 404 853 7429 | Bengaluru +91 80 6773 0202 | Beijing +86 10 6568 588 | Chicago +1 312 467 1331 | Dubai +971 4 584 6956 | Hong Kong +852 2623 0371 | London +44 207 961 4120 | Los Angeles +1 800 233 1614 | Melbourne +61 3 9939 8543 | Mexico City +55 5010 7600 | Mumbai +91 22 6284 5050 | Nantong +86 400 800 7429 | New York +1 212 953 7429 | Paris +33 (0) 1 81 22 44 39 | San Francisco +1 415 955 1920 | Shanghai +86 21 3338 4000 | Singapore +65 6733 1811 | Sydney +61 800 556 302 © 2026 Shaw Industries Group, Inc., a Berkshire Hathaway Company March 19, 2026
3 of 3
For reference purposes only if printed or downloaded.
CITY OF CARSON 701 East Carson Street
Report to Honorable Mayor and City Council
Tuesday, May 5, 2026, 5:00 PM
SPECIAL ORDERS OF THE DAY 32. To: Honorable Mayor and City Council From: Nathan Freeman, Director of Community and Economic Development CD Planning Subject: CONSIDER APPEAL OF PLANNING COMMISSION DECISION TO DENY DESIGN OVERLAYREVIEW NO.1935-23 AND CONDITIONAL USE PERMIT (CUP) NO. 1128-23, AND THE PLANNINGCOMMISSION'S RECOMMENDATION TO THE CITY COUNCIL REGARDING DENIAL OF DEVELOPMENTAGREEMENT (DA) NO. 33-23, FOR THE DEVELOPMENT OF AN APPROXIMATELY 100-MEGAWATT BATTERYENERGY STORAGE SYSTEM (BESS) LOCATED AT 18800 BROADWAY (APN: 7339-014-009) (CITY COUNCIL) I. SUMMARY
On March 10, 2026, the Planning Commission, by a 5-2 vote, adopted Resolution No. 26-2900, denying Design Overlay Review (DOR) No. 1935-23 and Conditional Use Permit (CUP) No. 1128-23, and recommending that the City Council deny Development Agreement (DA) No. 33-23 for an approximately 100-megawatt battery energy storage system (BESS) located at 18800 Broadway (Exhibit No.'s 2-4).
On March 23, 2026, Vesi 27 LLC (“Applicant”) filed a timely appeal of the Planning Commission’s decision. On April 16, 2026, the City Clerk determined the appeal to be complete and in compliance with Carson Municipal Code (CMC) Section 9173.4(B)(3) (Exhibit No. 5).
Section 9173.4 (Appeals) further provides that the City Council may take one of the actions described below within 60 days of filing an appeal; and unless the item is referred back to the Planning Commission, the City Council's decision must be supported by written findings.
Affirm Planning Commission Decision. The City Council can make this affirmation and uphold the Planning Commission's denial (see proposed Resolution No. 26-047 attached as Exhibit No. 6, which would also deny the DA as recommended by the Planning Commission); or
Modify Planning Commission’s Decision. Direct staff to prepare a resolution incorporating City Council direction and supporting findings as to any desired modifications. Due to the 60-day appeal action period expiring on Friday, May 22, 2026, such resolution would be brought back at the May 20, 2026 regular City Council Meeting; or
Refer the Matter Back to the Planning Commission with Instructions. This option may be considered if the City Council has significant issues requiring further analysis and would like the Planning Commission to reconsider the project. This path would necessitate the City Council to provide specific direction to staff and the Planning Commission; or
Reverse the Planning Commission’s Decision. Direct staff to prepare a resolution approving the project with appropriate findings, and subject to conditions of approval for consideration at a future City Council meeting.
Due to the 60-day appeal action period expiring on Friday, May 22, 2026, such resolution would be brought back at the May 20, 2026, Regular City Council Meeting.
Staff recommends that the City Council affirm the Planning Commission’s denial based on the findings set forth in draft Resolution No. 26-047.
II. RECOMMENDATION
TAKE the following actions:
1. OPEN the Public Hearing, RECEIVE public testimony, and CLOSE the Public Hearing; and EITHER
2. WAIVE further reading and ADOPT Resolution No. 26-047, “A RESOLUTION OF THE CITY COUNCIL OF
THE CITY OF CARSON, CALIFORNIA, AFFIRMING, PURSUANT TO CARSON MUNICIPAL CODE SECTION 9173.4(C)(2) (a), THE DECISION OF THE PLANNING COMMISSION TO DENY SITE PLAN AND DESIGN OVERLAY REVIEW NO. 1935-23 AND CONDITIONAL USE PERMIT NO. 1128-23, AND DENYING, AS RECOMMENDED BY THE PLANNING COMMISSION, DEVELOPMENT AGREEMENT NO. 33-23 FOR A PROPOSED BATTERY ENERGY STORAGE SYSTEM (BESS) FACILITY LOCATED AT 18800 BROADWAY AVENUE, APN 7339-014-009" (Recommended Action); OR
3. DIRECT staff to bring back a proposed resolution at the May 20, 2026 City Council meeting to modify the Planning Commission decision in accordance with Council direction provided at or upon the conclusion of the appeal hearing, and based on appropriate supporting written findings as discussed or considered at the appeal hearing; OR
4. REFER the matter back to the Planning Commission with specific instructions for further consideration; OR
5. DIRECT staff to bring back a proposed resolution on May 20, 2026, to reverse the Planning Commission’s decision and approve the project, supported by appropriate written findings and conditions of approval.
III. ALTERNATIVES
TAKE another action the City Council deems appropriate.
IV. BACKGROUND
On March 10, 2026, the Planning Commission held a duly noticed public hearing to consider a decision on DOR No. 1935-23 and CUP No. 1128-23, along with a recommendation to the City Council regarding DA No. 33-23, for a proposed 100-megawatt battery energy storage system at 18800 Broadway. Staff recommended denial of the project based on findings related to land use compatibility and public health and safety.
Following completion of the public hearing and consideration of the administrative record, the Planning Commission adopted Resolution No. 26-2900, denying the requested DOR and CUP entitlements and recommending City Council denial of DA No. 33-23, since the City Council is the decision-making body for development agreements. On March 23, 2026, the Applicant appealed the Planning Commission's decision to the City Council (Exhibit No. 5).
The City Council now must now consider the Applicant’s appeal and determine whether the Planning Commission’s decision should be affirmed, modified, reversed, or referred back to the Planning Commission. Unless referred back to the Planning Commission, the Council's decision on the appeal must be supported by written findings.
It should be noted that the Applicant may or may not be able to pursue alternative state-level review processes for certain energy infrastructure projects, including review by the California Energy Commission, which has jurisdiction over specified energy facilities under California law. However, the existence or potential availability of such processes does not alter the City Council's responsibility to evaluate the proposed project/appeal based on applicable local regulations, required findings, and the administrative record.
Site Context
The project site is located approximately 0.35 miles east of the I-110 Freeway and approximately 0.46 miles north of the I-405 Freeway. The project site is zoned M-H (Manufacturing - Heavy). The immediate surrounding area is primarily industrial; however, several sensitive receptors are located in proximity, including:
A Kaiser Permanente medical offices to the northwest, approximately 315' from the subject property line.
The City's Community Services/Public Works facility (which includes a secondary Emergency Operations Center) to the north, approximately 350' from the subject property line.
Residential uses east of Main Street, some of which are less than 500' from the subject property line.
Victoria Park to the southeast, commencing approximately 375' from the subject property line.
Towne Avenue Elementary School further to the southeast. (See Exhibit No. 1). The project site was previously occupied by an industrial topsoil operation and is currently vacant.
Project Description
The proposed project is an approximately 100 megawatt battery energy storage system BESS facility. In simple terms, the project would function like a large scale rechargeable battery for the electric grid, storing electricity when supply is high and releasing it when demand increases.
The facility would consist of lithium-ion batteries housed in enclosed steel containers, along with supporting electrical equipment such as inverters, transformers, switchgear, and a small on-site substation. These components work together to store electricity, manage the flow of power, and safely connect the facility to the regional electric system.
Each battery enclosure would contain racks of battery modules equipped with monitoring and communication systems that automatically track performance and operating conditions. A centralized battery management system would control when the batteries charge and discharge, while also regulating temperature through an integrated cooling system to maintain safe operation.
To connect the facility to the electrical grid, the project would include a new underground 66 kilovolt transmission line referred to as a gen-tie line. This line would run from the northeast portion of the site along the west side of Griffith Street and connect to the nearby Southern California Edison SCE Nola Substation, located approximately 165 feet east of the project site.
In addition, a fiber optic communication line would be installed to allow real time coordination between the project and SCE’s substation. Installation of this line would require trenching within the Griffith Street public right of way and would be subject to City approval, including any required easements or encroachment permits.
The facility would operate continuously 24 hours per day, 365 days per year, and would charge by drawing electricity from the grid and discharge by returning stored energy back to the grid when needed, helping to support overall grid reliability.
Key Considerations
Land Use Compatibility and Public Safety: the proposed project would introduce a large-scale lithium-ion battery energy storage facility into an urbanized area with nearby sensitive receptors. While such facilities provide regional energy benefits, they are also associated with risks, including thermal runaway events, fire, and the potential release of hazardous emissions.
Although modern BESS facilities incorporate monitoring and safety systems, the potential for failure events cannot be entirely eliminated. In this case, the proximity of residential uses, a school, a park, medical services, and critical City facilities increases the potential for off-site impacts in the event of an incident.
The Planning Commission determined that, given the site's location and surrounding context, the project raises land use compatibility concerns and may not adequately protect public health, safety, and welfare.
Emergency Response: Battery energy storage system incidents differ from conventional fires and may require specialized response strategies, including defensive operations, hazardous materials monitoring, and extended incident management. In the event of a significant system failure, response capabilities may be limited primarily to perimeter control, evacuation coordination, and incident monitoring. Given the proximity of sensitive receptors, the potential need for evacuation and extended incident duration presents additional challenges.
The Planning Commission found that these factors contribute to uncertainty regarding the City’s ability to adequately respond to a major incident at this location.
General Plan Consistency: The project supports certain General Plan goals related to energy innovation and sustainability. However, General Plan consistency must be evaluated as a whole. A project is consistent with the general plan if, considering all its aspects, it will further the objectives and policies of the general plan and not obstruct their attainment. Perfect conformity is not required, but the project must be compatible with the General Plan’s objectives, policies, uses, and programs.
The Planning Commission identified conflicts with key policies, including:
Land Use Compatibility and Community Health (Guiding Principle 6, Guiding Policy LUR-G-13, Guiding Policy CHE-G-4, Implementing Policy CHE-P-4): The scale, location, operational characteristics, and potential hazard profile of the project introduce land use compatibility and public health concerns relative to the surrounding area, which is characterized by dense urban development and includes nearby residential land uses and other sensitive receptors.
Hazardous Materials and Public Safety (CSES-G-14 and CSES-G-16): These policies emphasize minimizing exposure to hazardous materials and reducing risks to residents and workers. The proposed concentration of lithium-ion battery systems presents potential risks that the Commission determined could not be adequately mitigated in this location.
After considering all aspects of the project, the Planning Commission concluded that the project is not consistent with the General Plan.
Similarly, the Planning Commission also determined that the proposed use and development will not be compatible with the intended character of the area, which is a required finding for approval of a Conditional Use Permit (CUP), and that the development plan for the Project is incompatible with surrounding uses, which is a required finding for approval of a Site Plan and Design Review (DOR).
Additionally, the Planning Commission found that required findings to approve a Development Agreement (DA) include finding that the DA is consistent with the General Plan and will not be detrimental to the health, safety and general welfare. The Planning Commission determined these findings cannot be made as required to approve the proposed DA, and therefore recommended City Council denial of the DA.
V. APPEAL ANALYSIS
The appellant states that the Planning Commission erred by 1) disregarding community support and climate benefits, 2) contradicting evidence in the record, and 3) relying on a staff report containing material errors. Staff has reviewed each appellate concern and has provided the following responses.
Consideration of Community Support and Project Benefits The appellant states that the Planning Commission rejected community support and disregarded the project’s climate and community benefits. As noted, the Planning Commission conducted a duly noticed public hearing, received both written and oral testimony, and considered the full range of public input, including comments in support of the project.
The Planning Commission evaluates projects based on applicable findings (including the protection of public health, safety, and welfare), and not on the level of public support. After considering the project’s stated benefits and its potential risks, the Commission determined that the scale of the proposed facility, the location and proximity to sensitive receptors, and the concentration of hazardous materials presented public health and safety and land use compatibility concerns that exist despite the identified benefits. As a result, the Commission determined that it could not make all of the required findings for approval of the requested entitlements under the CMC.
One of the required findings for approval of a Conditional Use Permit under the CMC is, "If the Commission finds that any adverse effects will occur as a result of the proposed use and development, such effects must be found to be justified by the benefits to the public interest which will occur as a result of such use and development." The Commission found that adverse effects will occur as a result of the proposed use and development, and that such effects are not justified by the benefits to the public interest which will occur as a result of such use and development, including the proposed community benefits provided for in the proposed development.
Consistency with the General Plan and Evidence in the Record The appellant stated that the Planning Commission’s denial contradicts the facts and evidence, particularly with respect to General Plan consistency. While the project may comply with some General Plan goals related to innovation and renewable energy, the Planning Commission determined that other General Plan goals are not being met, as discussed above, and therefore is not consistent with the General Plan overall.
The Planning Commission determined that the project conflicts with key General Plan policies and does not warrant making the required CMC findings for approval of the requested entitlements. As further discussed above and in Planning Commission Resolution No. 26-2900, the basis for the Planning Commission's determination included the following:
Land Use Compatibility: Although the immediately adjacent area is industrially zoned, consideration of the proposed 24/7/365 battery storage and energy cycling operation, the site and location of the project, the development and uses in the surrounding area, the scale and concentration of hazardous materials proposed to be used in the project, and the potential for catastrophic fire and explosion events involving the project, based on substantial evidence in the record, results in concerns that the proposed use and development is incompatible with the surrounding industrial properties, which were not developed with adjacent utility-scale energy storage hazards in mind, as well as with the nearby sensitive receptors and other urban development.
As such, the project raises legitimate compatibility concerns.
CSES-G-14 and CSES-G-16 (Hazardous Materials and Public Safety): These policies emphasize minimizing hazardous material exposure and reducing risks to residents and workers. Lithium-ion batteries are hazardous materials. Lithium-ion battery storage systems are associated with documented risks, including thermal runaway, fire, explosion, and the release of toxic gases. Incidents involving BESS facilities in other jurisdictions (i.e. Vistra in Moss Landing, CA in 2025; Kearny South in San Diego in 2024, Gateway Energy Storage Facility in Otay Mesa, CA in 2024, McMicksen BESS in Surprise, AZ in 2020, etc.) demonstrate the plausibility of such risks. Even testimony and comment letters provided by the applicant or its representatives acknowledge that events of this nature continue to occur at BESS facilities in the United States every year and cannot be ruled out with respect to the project.
Given the project’s location within a densely developed urban environment, any failure event could have significant off-site consequences. Extensive testimony was provided by the Fire Chief at the Planning Commission hearing, which is outlined in the attached Planning Commission minutes (Exhibit No. 2) and can be viewed at https://horizon.agendalink.app/player/carsonca/6939a3d1dffef60047206fd7.
The Planning Commission determined, based on substantial evidence in the administrative record, that the project is inconsistent with General Plan policies and fails to satisfy other CMC requirements that are intended to ensure protection of public health and safety and compatibility of land uses as it pertains to approval of CUP's, DOR's and DA's for new uses and developments. The existence of evidence in the record that may support a different conclusion is immaterial to the validity of the City's decision. The City has discretion in determining whether or not the required findings for approval of the project entitlements are met, and the City's decision in that regard will not be disturbed so long as it is supported by substantial evidence in the record.
Alleged Errors in the Staff Report
The appellant states that the staff report contained material errors that influenced the Planning Commission’s decision. Staff responds as follows:
a. Characterization of Kaiser Permanente
While the staff report referenced Kaiser Permanente as a hospital, it is more accurately described as a medical office facility. However, this distinction does not diminish the fact that the medical office services vulnerable populations (i.e. the elderly obstetrics, and pediatrics). The facility also provides a wide range of healthcare services, including laboratory work, imaging and x-rays, pharmacy services, outpatient surgical procedures, and multiple medical specialties. As such, the facility can be reasonably classified as a sensitive receptor. b. Identification of Adjacent Uses and Sensitive Receptors The staff report correctly identified that properties immediately adjacent to the project site are industrial. However, it also appropriately noted that sensitive receptors exist in proximity of the subject property. Land use compatibility considers not only properties immediately adjacent to subject properties, but also considers nearby uses that could be affected by potential off-site impacts.
c. Potential Impacts from Toxic Smoke and Plume Modeling While modeling prepared for the project may not have identified significant impacts to specific receptors under certain assumed conditions, such analyses are limited by the scenarios evaluated. Recent incidents involving BESS facilities such as those mentioned above have demonstrated variability in fire behavior, duration, and emission characteristics that may not be fully captured in predictive models. Moreover, plume modeling does not eliminate the risk of hazardous emissions.
d. Location of BESS Facilities in Urban Areas
While the appellant notes that BESS facilities can and do operate in more urbanized settings, including an example in Pomona, this does not confirm that the proposed project is appropriate for proposed site. Each project must be evaluated on its own merits, including site characteristics, surrounding land uses, and proximity to receptors.
Conclusion
The Planning Commission’s decision to deny the DOR and CUP and recommendation to deny the DA was based on a full review of the material, public in-put, applicable findings, and General Plan policies. The Commission weighed the project’s potential benefits against its risks and identified valid concerns regarding land use compatibility and public health and safety.
For these reasons, staff recommends that the City Council uphold the Planning Commission’s decision.
VI. Environmental Review
A Class 32 exemption memorandum was prepared for the proposed project (see Exhibit No. 2). Pursuant to California Environmental Quality Act Guidelines Section 15332 (In-fill Development), Class 32 consists of projects characterized as in-fill development meeting the conditions described below:
a) The project is consistent with the applicable general plan designation and all applicable general plan policies as well as with applicable zoning designation and regulations. (b) The proposed development occurs within city limits on a project site of no more than five acres substantially surrounded by urban uses.
(c) The project site has no value as habitat for endangered, rare or threatened species. (d) Approval of the project would not result in any significant effects relating to traffic, noise, air quality, or water quality.
e) The site can be adequately served by all required utilities and public services.
The Planning Commission did not find that a CEQA Class 32 exemption applies to the project. Instead, the Planning Commission adopted a denial resolution that contains a finding of exemption pursuant to CEQA Guidelines Section 15061(b)(4), which provides that a project is exempt from CEQA if the project will be rejected or disapproved by the City.
V. FISCAL IMPACT
Development Impact Fees
If the City Councils determines to reverse the Planning Commission's decision, the project would be subject to Interim Development Impact Fees. In accordance with Article XI (Interim Development Impact Fee Program) of the Carson Municipal Code, the applicant, property owner, and/or successor to whom these project entitlements are assigned (“Developer”) shall be responsible for payment of a one-time development impact fee at the rate in effect at the time of issuance of building permits, currently (for Fiscal Year 2025-2026, effective July 1, 2025, through June 30, 2026) set at $3.68 per square feet for all square footage of battery enclosures (approximately 51,384 square feet). Based on the current rates, the interim development impact fees for the proposed development are estimated at $189,093.12. If the Project increases or decreases in size, the development impact fee amount will be adjusted accordingly at the same rate.
Development Agreement
The proposed Development Agreement would include the following payments to the City:
O & M payment: a lump sum amount of $357,006
Battery Fee: a guaranteed minimum payment of $250,000
VI. EXHIBITS
1. Project Location Map
2. March 10, 2026 Planning Commission Staff Report & Minutes
3. Supplemental Memo Denial Recommendation
4. PC Resolution No. 26-2900
5. Appeal Application from Vesi 27 LLC and Appeal Application Notice of Sufficiency
6. Draft City Council Resolution No. 26-047 Affirming Planning Commission Decision Attachments
Project Location Map.pdf
March 10, 2026 Planning Commission Staff Report & Minutes.pdf Supplemental Memo Denial Recommendation.pdf
PC Resolution 26-2900 _signed.pdf
Appeal Application from VESI 27 LLC & Appeal Application Notice of Sufficiency.pdf Draft Resolution No. 26-047 Affirming PC Decision and Denying DA_Griffith BESS.pdf Project
Site
City Corporation
YardKaiser
Permanente
Single Family
Homes
Single Family
Homes
W. Griffith Street
S. Broadway
S. Figueroa Street
M.L.K. Street
Main Street
Victoria
Community
Regional Park
SCE Nola
Substation
CITY OF CARSON 701 East Carson Street
Report to Planning Commission
Tuesday, March 10, 2026, 6:30 PM
NEW PUBLIC HEARING 9A.
TO: Planning Commission
FROM: McKina Alexander, Planning Manager
PREPARED
BY: Kaneca Pompey, Consultant Planner
SUBJECT: PUBLIC HEARING OF THE PLANNING COMMISSION OF THE CITY OF CARSON TO
CONSIDER FINDING A CEQA EXEMPTION, RENDERING A DECISION ON DESIGN OVERLAY REVIEW (DOR) NO. 1935-23 AND CONDITIONAL USE PERMIT (CUP) NO. 1128- 23, AND MAKING A RECOMMENDATION TO THE CITY COUNCIL REGARDING A DECISION ON DEVELOPMENT AGREEMENT (DA) NO. 33-23, FOR THE DEVELOPMENT OF AN APPROXIMATELY 100-MEGAWATT BATTERY ENERGY STORAGE SYSTEM (BESS) LOCATED AT 18800 BROADWAY (APN: 7339-014-009)
PROJECT/APPLICATION INFORMATION
Project
Summary:
A request by the applicant to consider finding a CEQA exemption, approving DOR No. 1935-23 and CUP No. 1128-23, contingent upon City Council approval of Development Agreement (DA) No. 33-23, and recommending the City Council adopt DA No. 33-23 for the development of an approximately 100-megawatt battery energy storage system (BESS) and project-related on-site and offsite improvements
Project
Location: 18800 Broadway (APN: 7339-014-009)
General
Plan/Zoning: Heavy Industrial/Manufacturing, Heavy
Project
Applicant: Jessica Mowry, ORMAT
Project Owner: VESI 27 LLC
I.
OVERVIEW
A. Introduction and Background
The approximately 3-acre vacant project site contains one parcel and is located in the northwestern portion of the city, south of Victoria Avenue, on the southeast corner of Griffith Street and Main Street. The proposed project includes an on-site approximately 100-megawatt battery energy storage system (BESS) development and project- related on and off-site improvements. The applicant/prospective permittee, and the contracting party under the proposed Development Agreement (DA) No. 33-23 and the contemplated shared easement agreement with the adjacent Edison substation, is VESI 27 LLC. The BESS site will be operated by Ormat Energy Storage (Ormat).
Ormat has over 60 years of experience in energy markets and currently operates eighteen (18) BESS projects across California, Ohio, and Texas.
From March 2019 to February 2025, the site was previously occupied by BD Topsoil and LA County Sandbags, an industrial topsoil supplier operation. Previous entitlement(s) for the project site include Tentative Parcel Map (TPM) 15195-82 to create two lots.
The applicant’s requested entitlements consist of the following:
DOR No. 1935-23, to approve the development plan for the project pursuant to CMC Section 9113.2 which designates the requirement for properties within a Design Overlay zone to be subject to CMC Section 9172.23 for Site Plan and Design Review for any development that is evaluated for $50,000 or more; CUP No. 1128-23, to approve the proposed BESS use containing hazardous materials pursuant to CMC Section 9141.1; and
DA No. 33-23, to grant specified development rights in exchange for provision of specified community benefits.
B. Project Description
The proposed project is an approximately 100-megawatt BESS consisting of lithium-ion batteries installed in refabricated steel enclosures housing internal racks, inverters, medium-voltage transformers, switchgear, collector substation, and other associated equipment to interconnect into the adjacent Southern California Edison (SCE) Nola Substation located east of the project site. The enclosures would have battery storage racks with relay and communications systems for automated monitoring and management of the batteries to ensure design performance. A battery management system would be provided to control the charging/discharging of the batteries, along with temperature monitoring and control of the individual battery cell temperature with an integrated cooling system. Power inverters to convert between AC and DC, along with transformers to step up the voltage, would also be included.
A single underground 66-kilovolt generation transmission line (gen-tie line) would interconnect the proposed project to the existing SCE NOLA substation. The proposed underground gen-tie line route would start at the northeast portion the project site, run east along the west Griffith Street frontage, and connect to the SCE Nola Substation located approximately 165 feet east of the project site, on the SCE Nola Substation property. To facilitate communication with SCE facilities, a fiber-optic cable will connect the project site switchyard with the SCE Nola Substation. Installation of the underground fiber optic cable lines would require trenching and earthmoving activities within the West Griffith Street public right-of-way and would be contingent upon City granting an easement or license to SCE or Developer, as applicable, for the location of the fiber optic cable lines in the West Griffith Street public right-of-way in exchange for fair market value consideration pursuant to a written agreement, and all required City encroachment and excavation permits.
The proposed BESS facility would provide a service to the regional electric grid by receiving energy (charging) from the SCE electric transmission system, storing energy, and then later delivering energy (discharging) back to the point of interconnection. The facility is intended to operate year-round and would be available to receive or deliver energy 24 hours a day and 365 days a year.
Proposed Site Plan:
Gen-tie and fiber line routes from Project Site to the SCE Nola Substation C. Existing Site Conditions
1. Zoning and General Plan Land Use Information
The project site is located approximately 0.35 miles east of the I-110 Freeway and approximately 0.46 miles north of the I-405 Freeway. Although the site and adjacent lots are primarily industrial uses, institutional use (Kaiser Permanente Hospital) is located further northwest, the City's Community Services/Public Works facility is located further north, a residential community is located east of Main St. across from the site, and Victoria Park and Towne Ave. Elementary School is located further to the southeast.
The 3-acre project and the project-related offsite improvements are within the Manufacturing, Heavy with Site Plan and Design review Overlay (MH-D) zone with a General Plan land use designation of Heavy Industrial (HI).
The following table summarizes the surrounding land uses, zoning, and general plan designations, as well as certain nearby sensitive receptors:
Land Use Summary Table
Existing Use Zoning General Plan
Subject Site Vacant MH-D
(Manufacturing,
Heavy -Design
Overlay)
Heavy Industrial
North of Subject
Site
Pactrans, LLC
(freight forwarding
office)
MH-D
(Manufacturing,
Heavy -Design
Overlay) and
ML-D
(Manufacturing
Light - Design
Overlay)
Heavy Industrial
Light Industrial
South of Subject
Site
OP Fleet Service
(truck repair)
MH-D
(Manufacturing,
Heavy -Design
Overlay)
Heavy Industrial
East (adjacent)
of Subject Site
Further
East/Southeast
(Across Main St.)
SCE Nola
Substation
Residential
neighborhood,
Victoria Park,
and Towne Ave.
Elementary School
MH-D
(Manufacturing,
Heavy -Design
Overlay)
Residential Single
Family and Open
Space
Heavy Industrial
Low Density
Residential and
Open Space
West of Subject
Site
Further
Northwest of
Subject Site
Metro Division 18
and
Kaiser Permanente
Hospital
ML-D
(Manufacturing,
Light -Design
Overlay)
Light Industrial
2. Site Conditions
The project site is currently vacant. The below photo shows the prior topsoil operation on the site. Vegetation consisting of ground cover (grass) and shade trees are located in planted areas within the frontage of the project site.
II. ANALYSIS
A. General Plan Consistency
The project site and project-related offsite improvements are located located within industrial area surrounded by existing development and within close proximity of sensitive receptors (hospital, park, residential, and school).
The General Plan land use designation for the project site is Heavy Industrial (HI). The heavy industrial designation is intended to provide for the full range of industrial uses that are acceptable within the community, but whose operations are more intensive and may have nuisance or hazardous characteristics, which for reasons of health, safety, environmental effects, or general welfare, are best segregated form other uses, and uses handling hazardous materials would be permitted only with proper safeguards and a conditional sue permit. The proposed use involves lithium ion batteries, which is a hazardous material, and is best segregated from other uses due not only to the batteries themselves but to the amount of energy they will be storing and the associated blast and fire hazards.
General Plan Policies:
Policy Project (In)Consistency
LUR-G-1: Maintain a
balanced land use
program that promotes
a diversified economic
base and capitalizes
on Carson’s location
and assets - strong
industrial economy,
access to major
freeways, rail
corridors, airports, and
the ports of Long
Beach and Los
Angeles, and the
presence of California
State University,
Dominguez Hills
The Project adds
regionally serving
industrial use which will
generate tax revenue and
community benefits for the
City (See Development
Agreement, Article 3). The
proposed project
capitalizes on the
presence of the nearby
SCE Nola Substation.
LUR-G-15: Prioritize
uses that provide
services to the
community, generate
sales tax, generate
good paying jobs, or
provide other benefits
to the community.
The Project would provide
a service to the regional
electric grid, and the initial
development of the
Project will generate sales
tax revenue and
community benefits for the
City (See Development
Agreement). The Project
construction would employ
good paying union labor
jobs. In operation, the
Project would be remotely
monitored and would only
require intermittent on-site
maintenance, meaning
there will be very few
employees on-site (and
frequently none) and the
Project operation will not
involve heavy trucking.
Tesla, the battery
manufacturer, would
employ labor for Project
operations and
maintenance.
CIR-G-5: Manage
parking demand and
supply through the
provision of adequate
and convenient
facilities
The Project would have
insignificant traffic impact
and parking demands, and
provides four off-street
parking spaces for the
occasional maintenance
visits.
Guiding Principle 6:
Foster harmony
between industrial and
residential land uses.
LU-7: Adjacent land
uses that are
compatible with one
another.
LUR-G-13: Ensure
adequate buffers and
transitions between
industrial and
residential land uses
as sites are developed
or redeveloped.
Area of Concern. The
Project would contain
hazardous materials in the
form of a large volume of
lithium-ion batteries
intended to store
electricity, involves a risk
of fires and explosions
emitting or ejecting
materials from the Project
site, and is located on a
relatively small (3-acre)
site that is surrounded by
existing industrial
development and is in
proximity to multiple
sensitive uses (Kaiser
Permanente Hospital,
residential neighborhood
east of Main St., and
Victoria Park, as well as
the City's Corporate Yard,
all within 1,000 feet).
Towne Avenue Elementary
School and one or more
daycare uses are slightly
further away.
LU-7: Adjacent land
uses that are
compatible with one
another.
CHE-G-4: Protect
community health from
pollution by toxics and
hazardous materials,
especially in areas
with vulnerable or
sensitive populations.
CSES-G-14: Protect
Carson residents and
workers from
hazardous material
exposure and
minimize the threat to
public health and
safety and to the
environment posed by
a release of hazardous
materials.
CSES-G-16: Continue
mitigating against and
restricting hazardous
material usage in
efforts to reduce
pollution and hazard
burden on Carson
residents.
The Project would comply
with applicable federal,
State, and local standards
that would help to mitigate
any potential adverse
impacts related to an
accidental release of
hazardous materials
during construction or
operation of the Project.
Area of Concern. Lithium
battery systems have
documented risks of
thermal runaway, fire,
explosion, and toxic gas
release. BESS facilities
such as the project carry
potential off-site public
health and safety impacts
resulting from explosions
and fires involving the
BESS facilities. There
have been several recent
failures of outdoor utility-
scale containerized-BESS
(like the Project) in other
jurisdictions, mostly in
remote areas. Until
recently, BESS facilities
have much-more
commonly been installed
in such remote areas,
whereas the Project site is
in a densely developed
area. If a failure incident
occurred on the Project
site, the consequences to
public health and safety
could be far more grave
than a similar incident
occurring in a remote
area. Fires involving
BESS facilities must be
simply contained and
allowed to burn
themselves out, meaning
the hazardous materials
would be consumed and
emitted in the smoke.
Explosions involving
BESS facilities can eject
projectiles high into the air,
so although a blast wall
can contain horizontal
projectiles, it may not
prevent a rain-down effect
on surrounding properties.
B. Zoning Ordinance Compliance
The proposed project is consistent with applicable development standards pursuant to CMC Sections 9146.23- 9146.25. However, the Zoning Ordinance does not specifically address BESS uses.
Development Standards
Criteria Required Provided
Front Yard 25 feet 25 feet
Side Yard 10 feet 15 feet
Rear Yard N/a 3 feet
Wall Not to exceed 50 feet 6 foot wrought iron fence, and 10 foot perimeter cmu block wall
Parking n/a 4
III. ANALYSIS OF ENTITLEMENTS (DOR, CUP, and DA)
A. Site Plan and Design Review (DOR) No. 1935-23
Section 9172.23 (Site Plan and design Review) states that the Planning Commission shall approve a DOR if the commission is able to make the following affirmative findings:
a. Compatibility with the General Plan, any specific plans for the area, and surrounding uses. b. Compatibility of architecture and design with existing and anticipated development in the vicinity, including the aspects of site planning, land coverage, landscaping, appearance and scale of structures and open spaces, and other features relative to a harmonious and attractive development of the area. c. Convenience and safety of circulation for pedestrians and vehicles. d. Attractiveness, effectiveness and restraint in signing graphics and color. e. Development scheduling (if phased development) which will satisfy the above criteria in each phase. f. Conformance to any applicable design standards and guidelines which have been adopted pursuant to CMC 9172.15. Such design standards and guidelines may be generally applicable or may specify different requirements for different areas.
The proposed project and project-related offsite improvements includes the development of energy storage facilities and associated infrastructure within an Industrial zone. With the inclusion of the conditions of approval, the proposed project is designed to be compatible with zoning code development standards and design regulations and would adhere to allowable building height and setbacks. The proposed development placement is located approximately 38.5 feet from the front property line, behind landscaped areas and a decorative concrete 6-foot-high wrought iron fence along Broadway and a 10-foot-high CMU block wall around the perimeter of the site. However, BESS facilities have documented risks of thermal runaway, fire, explosion, and toxic gas release and staff has concerns about the proposed project's potential to have an incident resulting in off-site public health and safety impacts to the surrounding business, institutional, park and residential communities.
Architecture and Design
The proposed BESS development plan includes the following facilities and project-related offsite improvements.
BESS Enclosures
The enclosures would be approximately 9 feet in height, with equipment placed on a concrete pad. The proposed BESS would be designed and installed in conformance with the nationally recognized National Fire Protection Association (NFPA) 855 Standard for the Installation of Stationary Energy Storage Systems, along with all applicable State and City fire protection requirements. The BESS would be unstaffed, with remote operational control and periodic on-site inspections and maintenance performed as necessary.
Batteries and Racks
The proposed lithium-ion batteries would be housed on racks, similar to common computer server racks. The racks are typically made of aluminum but may be composed of steel. The battery racks would be designed and installed in accordance with local seismic design requirements. The batteries/battery enclosures would be manufactured by/purchased from Tesla, and are a product known as the Tesla Megapack XL2.
Outdoor Electric Equipment
The proposed project includes transformers and additional electrical equipment that would be installed outside the BESS enclosures. The collector substation would be located to the east of the BESS facility components, and would be surrounded by an internal chain link fence which would not be visible from outside the property. Components would include a main power transformer, control house, and switchgear.
Underground wires and cabling would run from the battery cable collection box (inside the enclosure) to a concrete pad housing the inverter and transformer. From the transformer, cabling would be run to the collector substation. All outside electrical equipment would be housed in the appropriate National Electrical Manufacturers Association (NEMA) rated enclosures and screened from view to the extent possible, on all sides. All outside electrical cabling on the site will be run underground.
Power Inverters and Transformers
Industry-standard nationally recognized equipment would be installed as part of the proposed project and project-related offsite improvements. The power inverters would be unattended stand-alone units that operate in all conditions. Inverters operate in both a charge mode and a discharge mode and are monitored and controlled remotely. In the event of an emergency or unscheduled maintenance, on-site disconnects would be utilized. Power inverters and transformers are designed to be robust with an anticipated life-span of approximately 30 years with proper maintenance.
Collector Substation
The proposed collector substation would include an open rack, air-insulated switch gear, and the main power transformer to step up medium-voltage. The substation area is anticipated to be located in the northeast corner of the BESS area.
Generation Transmission Line (Gen-tie Line)
A single 66-kilovolt generation transmission line (gen-tie line) would interconnect the proposed project to the existing SCE NOLA substation. The proposed gen-tie line route would start at the northeast portion the project site, run east along the west Griffith Street frontage, and connect to the SCE Nola Substation located approximately 165 feet east of the project site, on the SCE Nola Substation property.
Landscape
The project is proposing approximately 6,093 square feet of landscaping. Landscaping includes ground covers, shrubs, and three different tree species. The proposed landscaping would utilize low water use climate adapted plants and would improve the streetscape while providing additional screening for the proposed project. The project’s landscaping would comply with all City and State requirements.
Operations and Maintenance Storage Area (O&M)
O&M storage area is proposed at the eastern portion of the project site. The O&M storage will consist of two 40-foot-long storage containers and two 20-foot-long storage containers. The area would house equipment and materials necessary to complete O&M activities. The O&M storage area would be unmanned with no personnel facilities such as restrooms, showers, etc.
Signage
No signage is proposed at this time. Any future proposed signage shall comply with all City requirements pursuant to CMC Sections 9146.7 (Industrial Signs) and 9172.23 (Site Plan and Design Review).
Site Access, Parking, Traffic, and Security
Access to the project site would be provided via two driveways (one existing and one proposed) along Broadway.
No new roads would be required to provide access to the project site. A paved 26-foot-wide internal access road would surround the BESS portion of the project site. The proposed project includes four (4) parking spaces on site near the proposed operations and maintenance (O & M) storage area in compliance with the Zoning Ordinance parking requirements. The project would generate very few traffic trips, as the BESS facility would not be open to the public and would not involve daily employee staffing or truck servicing. The proposed project and project- related offsite improvements would be unoccupied and monitored remotely. Minimal periodic employee visits would be conducted for on-site equipment inspections, monitoring, and testing. Permanent motion-sensitive, directional security lights would be installed to provide adequate illumination around the substation area and points of ingress/egress. Pursuant to City of Carson Municipal Code (CMC) Section 9127.1, all exterior lighting installed on the project site would be shielded and directed downward to minimize the potential for glare or spillover onto adjacent properties. Security cameras would be placed throughout the project site and monitored 7 days a week and 24 hours per day as deemed appropriate by the Los Angeles County Sheriff Department.
Telecommunication Facilities
The proposed project would require telecommunication facilities to meet the communication requirements for interconnecting and communicating with the SCE/ California Independent System Operator (CAISO) facilities and to support remote project operations monitoring. To provide for communication with SCE facilities, a fiber-optic cable would be used to connect the project site switchyard with the SCE point of interconnection. Utility interconnection regulations require the installation of a second, separate, redundant fiber-optic cable. The redundant fiber-optic cable would also be installed within the project footprint. The project would use local exchange carrier services for telecommunication to support remote monitoring requirements. The project would connect to telecommunication fiberoptic lines owned and managed by local telecommunication providers.
Trash Enclosure
A three-sided trash enclosure with a self-closing gate is proposed near the project’s southeastern boundary and would be approximately 7 feet in height and 11 feet, 3 inches in width. Design standards are pursuant to CMC Sections 9164.3-9164.5.
Wall
Per the Conditions of approval, a reinforced, 10-foot-high, decorative CMU block wall would be installed around the perimeter of the project site for safety and security purposes. The wall shall be a containment wall, engineered to withstand and contain the blast hazard associated with the Project, to the reasonable satisfaction of the City Engineer and the Los Angeles County Fire Marshal or designee. A 6-foot wrought iron fence and access gate at the driveway entrance are proposed along the project frontage on Broadway. All gates would be equipped with Knox boxes for emergency access. The decorative CMU block wall will be a natural, muted color designed in such a way that provides an aesthetically visual enhancement from the street view, public places, and adjacent properties. The City Traffic Engineer and the Los Angeles County Fire Department, Fire Prevention Land Development reviewed and approved of these proposed conditions of approval.
Below are renderings illustrating the BESS development.
Proposed View from Broadway Avenue
Proposed View from Griffith Street
Proposed View North
Proposed View East
Although the site is designated Heavy Industrial, the proposed development plan presents potential explosion and fire hazards. The project site is surrounded by existing development and is in close proximity to multiple sensitive uses including a Kaiser Permanente hospital to the northwest, a residential area approximately 500 feet away to the east, Victoria Park to the southeast within 1,000 feet, and Towne Elementary School and at least one daycare use slightly further to the east. The potential public health and safety risks presented by the project create compatibility concerns with the surrounding uses and sensitive receptors. Additionally, although the immediately adjacent area is industrially zoned, the proposed 24/7/365 battery storage and energy cycling operation, the scale and concentration of hazardous materials proposed to be used in the project, and the potential for catastrophic fire and explosion events involving the project results in concerns that the proposed development is incompatible with the surrounding industrial properties, which were not developed with adjacent utility-scale energy storage hazards in mind. Furthermore, although the Project has completed Fire Department Alternate Materials and Methods (AMMR) review, the proposed Fire Department conditions of approval requiring risk mitigating measures such as blast walls do not negate the Project’s risks to public health and safety. For example, although the blast wall could contain horizontal projectiles, it may not contain rain-down effects from an explosion, and the AMMR review and conditions do not preclude the possibility of a fire involving the BESS facility emitting toxic smoke that could affect surrounding uses and sensitive receptors.
B. Conditional Use Permit No.1128-23
Carson Municipal Code Section 9172.21 (Conditional Use Permit) states that the Commission shall approve a CUP if it is able to make the following affirmative findings:
a. The proposed use and development will be consistent with the General Plan. b. The site is adequate in size, shape, topography, location, utilities, and other factors to accommodate the proposed use and development.
c. There will be adequate street access and traffic capacity. d. There will be adequate water supply for fire protection. e. The proposed use and development will be compatible with the intended character of the area. f. Such other criteria as are specified for the particular use in other Sections of this Chapter The 3-acre site adequately accommodates the proposed BESS development. Fire Department conditions of approval have been included in the project's conditions of approval. Adequate street access is provided via Broadway. The lithium-ion batteries, which are hazardous materials, are on racks in battery enclosures. As designed and conditioned, certain safeguards will be in place before any operation of the Project, including a reinforced 10-foot-high CMU block wall around the entire perimeter of the property.
Additionally, per the Conditions, none of the battery enclosures shall be within 25’ of any property line, and the battery enclosures shall be equipped with internal, fail safe heat and gas detection and alarm systems, which shall provide audio and visual early warnings of increases in heat or gas in any battery enclosure to a third-party reporting station that actively monitors for such warnings on a 24/7/365 basis.
Whenever any of the batteries fail, reach the end of their useful life, or need to be disposed of due to a legal requirement or due to their continued presence posing an added risk to public health or safety, the developer shall promptly discontinue use and dispose of such batteries in accordance with all applicable laws and regulations, including but not limited to those related to hazardous materials and hazardous waste. As described above, per the General Plan, uses handling hazardous materials on properties designated Heavy Industrial cannot be permitted without proper safeguards and a conditional use permit.
The required conditions of approval set forth in CMC 9141.1 associated with issuance of conditional use permits for uses that involve hazardous materials have been incorporated into the Conditions, and additional health and safety measures have been incorporated into the Conditions as discussed above, in addition to the conditions pursuant to the Fire Department's AMMR review.
However, when a failure occurs involving a BESS facility, due to a number of life-safety reasons (i.e., explosion potential and toxic exposure, coupled with the fact that suppression efforts are ineffective and cause potentially-contaminated runoff, and exposure-protection efforts can actually cause failures in otherwise-unaffected units), it is anticipated that there is little to nothing the Fire Department would be able to do to intervene during these incidents other than to ensure that evacuation of the area has occurred (on and off site, depending on the incident type), coordinate site-operator activities as the incident commander, and monitor the situation. Stated differently, a fire involving a BESS facility generally cannot be put out, but rather must be allowed to burn itself out, which would occur once all the lithium-ion batteries and other involved materials have been consumed and emitted into the air as toxic smoke, which could then be carried by the wind affecting air quality and leading to severe public health and safety hazards for nearby sensitive receptors and other existing uses and developments.
Based on the relative frequency at which BESS-site failures continue to occur, fire incidents are expected to likely occur during the 15-to-30-year lifespan of the BESS units to be installed and the proposed 20-year term of the development agreement.
C. Development Agreement No. 33-23
The proposed DA is required to comply with the procedures established by the City Council as required by Government Code Section 65865(c) and the provisions of Government Code Sections 65864 through 65869.5, the State development agreement law. The applicant applied for a Development Agreement (DA) detailing the obligations of both the Applicant and City of Carson, and specifying standards and conditions that will govern the project for the proposed term of the DA, which would be until March 1, 2047, with options to extend to as late as March 1, 2052, or until the Developer's leasehold interest in the subject property ends, whichever is sooner. The DA, for its term, confers vested rights to the Developer as described in Articles 4-5 of the DA in exchange for the provision of public/community benefits to the City as provided in Article 3 of the DA. Approval of the proposed DA requires a finding that it is consistent with the City’s General Plan and will further the overall public health, safety, and welfare in the City. The applicant has entered into a contract giving it an option to lease the Property for a period of twenty (20) years from the time the option is exercised, and as such, possesses the requisite legal or equitable interest in the Property under Government Code §65865 that allows it to enter into the DA.
Article 3 of the DA outlines the public benefits that the project will contribute towards community public benefits to the City. The community benefits include: payment of Interim Development Impact Fees (IDIF) per the City’s Municipal Code (anticipated to be $189,093.12 if paid during FY 25-26); payment of a “O & M Payment” in the amount of $357,006; and payment of a “Battery Fee” as set forth in Section 3.3 (in an amount that could be anywhere from $250,000 to $1,487,500, depending on whether and to what extent the project batteries are purchased in a way that generates sales tax revenue for the City), in addition to likely generating significant sales tax revenue to the City from the purchase of project batteries. If the project battery purchase generates no sales tax (including applicable Bradley Burns sales and use tax and City transaction and use tax) revenue for the City, the Battery Fee amount will be the maximum amount of $1,487,500; for every dollar of tax revenue generated to the City by the purchase of project batteries, the Battery Fee amount will be reduced by a dollar, to a minimum Battery Fee amount of $250,000. The City will receive the applicable Battery Fee amount in addition to any and all sales tax revenue generated for the City by the project. The proposed DA provides for a public convenience through significant monetary benefits which will contribute to programs and services designed to provide for the health, safety, and welfare of the public, thereby exhibiting good land use practices. The proposed project will also provide additional health & safety features as detailed in the Conditions.
IV. COMMUNITY OUTREACH
Over the last two years, the applicant has conducted four neighborhood community meetings, including two meetings in 2024 and two meetings in 2026.
July 1, 2024 Community Meeting at Victoria Park
The first community meeting was held at Victoria Park, a location intentionally selected for its accessibility to nearby residents and its close proximity to the project site. Ormat hosted the meeting from 2:30 to 4:30 pm and remained on site from 12:00 to 5:00 pm to maximize opportunities for community members to attend, ask questions, and engage directly with the project team. No attendees arrived.
August 13, 2024 Community Meeting at Stevenson Park
The second community meeting was held at Stevenson Park. On behalf of Ormat Technologies, the City mailed notices to all residents and businesses within an increased specific radius of the project site. Ormat hosted the meeting from 6:30 to 8:30 pm. The meeting was structured as an open forum, supported by a presentation, and attendees were encouraged to ask questions throughout. Eight community members attended the meeting.
Following the meeting, Ormat continued its engagement with nearby residents by proactively sharing additional information with community members who requested follow-up. Speakers expressed safety concerns during and after the meeting.
January 13, 2026 Community Meeting at Towne Avenue Elementary School On December 29, 2026, mailers with addresses provided by the city were sent to area residents and businesses surrounding the project site for the third community meeting. In addition to the mailers, the applicant reached out to the Carson Chamber of Commerce, Towne Avenue Elementary School staff, parents, and students, personnel from IBEW Local 11, and staff from after school programs hosted by the Boys and Girls Club.
The third community meeting was held at Towne Avenue Elementary School and Ormat hosted the meeting from 5:30 to 7:30 pm. A total of six community members attended, including staff from the Los Angeles County Fire Department. Community members expressed support for the project.
February 10, 2026 Community Meeting at Stevenson Park
The fourth and final community meeting, hosted by Ormat, was held at the Stevenson Park Multi-Purpose Room from 6:00 to 8:00 pm. Prior to the meeting, the city mailed a notices to residents and business owners located in a 1,000 foot radius of the project site. Attendees to this meeting included members of the Carson Chamber of Commerce, Towne Avenue Elementary School, the Boys and Girls Club of Carson, Collab CDC, and representatives from IBEW Local 11. In addition to the outreach noted above, the project team collaborated with Towne Avenue Elementary School staff to share additional information on ClassDojo for interested parents and requested the project mailer be disseminated at the Chamber of Commerce Mix and Mingle event. Approximately 12 people attended the meeting, and four comment cards were submitted, all of which were either supportive or expressed interested in receiving ongoing updates.
V. PROJECT CONCERNS
Public Safety and Fire Risk
Large-scale lithium-ion battery storage facilities present a documented risk of thermal runaway events, which can result in the following:
1. Intense, difficult to extinguish fires
2. Prolonged burn duration and potential re-ignition
3. Release of toxic gases, smoke and particulate matter
4. Off-site impacts requiring evacuations
5. Explosions and projectiles, including rain-down effect projectiles although horizontal projectiles may be contained by blast walls
Although modern systems include monitoring and suppression technologies, the risk cannot be eliminated. The subject property is in proximity to the City's Public Facilities Yard and sensitive uses, including residential neighborhoods, hospital, park, and an elementary school. This dense surrounding existing development and proximity to sensitive uses amplifies potential impacts in the event of failure.
Emergency Response Capacity
Lithium-ion battery fires differ significantly from conventional structure or industrial fires.
They often require:
1. Defensive firefighting strategies
2. Hazardous materials monitoring
3. Extended incident command operations
4. Evacuation coordination
Moreover, BESS facilities are not without potential off-site consequence/impact and much remains unpredictable.
There have been several recent failures of outdoor utility-scale containerized-BESS (like the proposed project), mostly in remote areas. Traditionally, BESS facilities have generally been installed in remote areas, unlike the proposed Project. If a failure incident occurred, for a number of life-safety reasons (i.e., explosion potential and toxic exposure, coupled with the fact that suppression efforts are ineffective and cause potentially-contaminated runoff, and exposure-protection efforts can actually cause failures in otherwise-unaffected units), it is anticipated that there is little to nothing the Fire Department would be able to do to intervene during these incidents other than to ensure evacuation of the area has occurred (on and off site, depending on the incident type), coordinate site- operator activities as the incident commander, and monitor the situation. Based on the relative frequency at which BESS-site failures continue to occur, fire incidents are expected to occur during the 15-to-30-year lifespan of the BESS units to be installed.
VI. ENVIRONMENTAL REVIEW
The proposed approval resolution contains a finding that the project is categorically exempt from the California Environmental Quality Act (CEQA) pursuant to CEQA Guidelines Section 15332 (Class 32), based on a Class 32 exemption memorandum that was prepared for the proposed project (Attachment 5).
Class 32 consists of projects characterized as in-fill development meeting the conditions described below:
a) The project is consistent with the applicable general plan designation and all applicable general plan policies as well as with applicable zoning designation and regulations. (b) The proposed development occurs within city limits on a project site of no more than five acres substantially surrounded by urban uses.
(c) The project site has no value as habitat for endangered, rare or threatened species. (d) Approval of the project would not result in any significant effects relating to traffic, noise, air quality, or water quality.
e) The site can be adequately served by all required utilities and public services.
The proposed denial resolution contains a finding of exemption pursuant to CEQA Guidlines Section 15061(b)(4), which provides that a project is exempt from CEQA if the project will be rejected or disapproved by the City.
VII.
PUBLIC HEARING NOTICE
Notice of this public hearing was given in accordance with Chapter 9173.22 of the CMC. The Planning Division mailed notification to property owners and occupants within a 1000-foot radius of the site and published notice in a newspaper of general circulation, and posted notices on-site by February 18, 2026. As of noticing and writing this report, three public comments were received.
VIII. RECOMMENDATION
That the Planning Commission:
1. Open the public hearing;
2. Receive and file the staff report and all related testimony;
3. Close the public hearing; and
4. Deliberate and take action at the discretion of the Planning Commission, including considering potential adoption of one of the following Resolutions:
1. Resolution No. 26-2900, entitled “A RESOLUTION OF THE PLANNING COMMISSION OF THE CITY
OF CARSON FINDING A CEQA EXEMPTION AND CONDITIONALLY APPROVING SITE PLAN AND DESIGN REVIEW NO. 1935-23 AND CONDITIONAL USE PERMIT NO. 1128-23 CONTINGENT UPON
CITY COUNCIL ADOPTION AND APPROVAL OF, AND RECOMMENDING THAT THE CITY COUNCIL ADOPT AND APPROVE, DEVELOPMENT AGREEMENT NO. 33-23, FOR A PROPOSED BATTERY ENERGY STORAGE SYSTEM (BESS) FACILITY LOCATED AT 18800 BROADWAY AVENUE, APN 7339-014-009"; or
2. Resolution No. 26-2900, entitled "A RESOLUTION OF THE PLANNING COMMISSION OF THE CITY OF CARSON DENYING SITE PLAN AND DESIGN REVIEW NO. 1935-23 AND CONDITIONAL USE PERMIT NO. 1128-23, AND RECOMMENDING THAT THE CITY COUNCIL DENY DEVELOPMENT AGREEMENT NO. 33-23, FOR A PROPOSED BATTERY ENERGY STORAGE SYSTEM (BESS) FACILITY LOCATED AT 18800 BROADWAY AVENUE, APN 7339-014-009".
IX. ATTACHMENTS
1. Draft Resolution No. 26-2900 (Conditionally Approving the Project) A. Legal Description
B. Conditions of Approval
2. Draft Resolution No. 26-2900 (Denying the Project)
A. Legal Description
3. Radius Map
4. Project Plans
5. Class 32 Exemption Memorandum
6. Draft Development Agreement
7. Public Comment Letters
Attachments
Draft PC Resolution Conditionally Approving Project(2101001.3).pdf Draft PC Resolution Denying Project(2100261.3).pdf
Radius Map.pdf
Project Plans.pdf
Class 32 Exemption Memorandum.pdf
Draft Development Agreement _Griffith BESS (PC 3.10.26)(962849.18).pdf Public Comments
Date: March 10, 2026
To: Planning Commission
From: Nathan Freeman, Community and Economic Development Director Concurred by: McKina Alexander, Planning Manager
Prepared by: Kaneca Pompey, Senior Planner and McKina Alexander, Planning Manager
SUBJECT: SUPPLEMENTAL MEMORANDUM TO CLARIFY STAFF’S RECOMMENDATION MARCH 10, 2026 PLANNING COMMISSION AGENDA
ITEM 9A DESIGN OVERLAY REVIEW (DOR) NO. 1935-23, CONDITIONAL USE PERMIT (CUP) NO. 1128-23, AND DEVELOPMENT AGREEMENT (DA) NO. 33-23 FOR A PROPOSED BATTERY ENERGY STORAGE SYSTEM (BESS) AT 18800 BROADWAY
The published staff report include d two draft resolutions for the Planning Commission’s consideration:
one recommending approval of the project and the other recommending denial. This supplemental memorandum clarifies the staff recommendation for the Planning Commission March 10, 2026 published Agenda regarding Item 9A the proposed Battery Energy Storage System (BESS) project (Giffith St. BESS) located at 18800 Broadway, Carson, CA.
To clarify the record , the following reflects staff’s recommendation for the Planning Commission consideration of Item 9A:
RECOMMENDATION
1. OPEN the public hearing, take public comment, and CLOSE public hearing; and
2. ADOPT Resolution No. 26-2900, entitled
"A RESOLUTION OF THE PLANNING COMMISSION OF THE CITY OF CARSON DENYING SITE PLAN AND DESIGN REVIEW NO. 1935 -23 AND CONDITIONAL USE PERMIT NO. 1128 -23, AND RECOMMENDING THAT THE CITY COUNCIL DENY DEVELOPMENT AGREEMENT NO. 33 -23, FOR A PROPOSED BATTERY ENERGY STORAGE SYSTEM (BESS) FACILITY LOCATED AT 18800 BROADWAY AVENUE, APN 7339-014-009."
The draft resolution recommending approval of Item 9A will be removed from consideration. No other revisions to the staff report or its attachments are proposed.
Nathan Freeman
Community and Econoomic Development Director
01007.0632 2100261.3