50781055.1/005890.00001
With respect to insurance coverage for any matters covered by the scope of services under this Agreement, you agree that it is your own responsibility, rather than the Firm’s responsibility, to identify potential insurance coverage and to tender legal matters to any appropriate insurance companies that may insure you. If you desire that the Firm become involved in identifying potential insurers and/or the tender of legal disputes, then a separate written agreement between you and the Firm to that effect will be required.
The Firm will not settle, negotiate or compromise the Matter without your consent.
Assignment of Firm Personnel. I will be primarily responsible for the supervision of the Matter, but you are engaging the Firm, not me individually. As and when necessary, I will draw upon the talent and expertise of other attorneys and paralegals along with legal assistants to handle this Matter.
Communication by Firm. The Firm will keep you regularly and currently informed of the status of the Matter and will consult with you when appropriate. Copies of significant correspondence and documents will be sent to the person designated by you from time to time for that purpose. In the event that you need to reach the Firm and the person sought is unavailable, please leave a message for the person concerned, disclosing the nature and urgency of the call. It is the Firm’s policy that all calls will be returned promptly and in any event no later than within one business day of receipt of the call. If you have not received a return call within that time, please call again.
Client Cooperation. You understand and agree that, in order for the Firm to represent you effectively, it is necessary for you to assist and cooperate with the Firm during this engagement.
You agree to (1) make yourselves (including your employees, if applicable) available to discuss issues as they arise in this matter; (2) attend and participate in meetings, preparation sessions and court proceedings, review drafts of documents, and perform other activities in connection with the representation; and (3) provide complete and accurate information and documents to us on a timely basis. Your non-cooperation will be grounds for the Firm’s withdrawal from representing you. It is essential that you and the Firm maintain open communications.
Protection of Client Confidences – High Tech Communication Devices. The Firm stays constantly aware of its important obligation to preserve the secrets and confidences of its clients which it holds in precious trust for them. To that end it is important that you and the Firm agree from the outset what kinds of communications technology the Firm should employ in the course of this engagement. For instance, the exchange of documents and other information using email or other types of electronic communications involves some risk that information will be retrieved by third parties with no right to see it. Even the use of facsimile machines can cause problems if documents are sent to numbers where the documents sit in open view.
Therefore, you should only provide the Firm with cellular numbers, facsimile numbers and email addresses which are acceptable to you for receiving confidential communications from the Firm. 467
AT KI NS O N, AND E L SO N, L O YA, RUUD & ROMO
Angela C. Lopez, Executive Director HR
City of Ontario
June 12, 2024
If you have any mailing addresses, cellular numbers, facsimile numbers, and email addresses that the Firm should not use for confidential communications, please advise us of these in writing. You agree that the Firm may use any of your cellular numbers, facsimile numbers and email addresses other than those which you specify in writing that the Firm should not use. You can use the Technology Questionnaire form at the end of this letter for this purpose.
During the course of our representation of you, it may be necessary to wire transfer funds to the Firm. We will always provide the Firm’s banking information in an encrypted email. Do not rely upon any future purported email from the Firm that changes the wire transfer information without confirming that change through a telephone call directly with a Firm attorney.
Term. The term of this Agreement shall be from July 1, 2024, to June 30, 2027, unless earlier terminated as provided herein. The City shall have the unilateral option, at its sole discretion, to renew this Agreement automatically for no more than two (2) additional one-year terms.
Consultant shall complete the Services within the term of this Agreement, and shall meet any other established schedules and deadlines. The Parties may, by mutual, written consent, extend the term of this Agreement if necessary to complete the Services.
Fees and Expenses. The Firm’s fees are generally based on the actual time spent on the Matter by the Firm’s attorneys, paralegals and legal assistants. Each has an hourly rate at which his or her time is charged. That rate is set by the Firm, taking into consideration the individual’s professional expertise and other relevant factors. Generally, these rates are revised in November of each year. The current hourly rates are $250 to $990 per hour for the Firm’s attorneys and $225 to $290 for the Firm’s paralegals. Attorney’s time will be recorded in hours and tenths of hours (six minute units) with a minimum entry of two tenths of an hour. Rates for legal assistants and others who perform services for you will be reflected on the invoices issued to you. It is contemplated that the Firm will, and the Firm reserves the right to, increase its hourly rates each year effective each January 1 after the execution of this Agreement, unless the Agreement is canceled or this provision is modified in writing. Generally, the Firm increases its annual rates by $10. John Bakhit's 2024 hourly rate is $395. Firm agrees to honor these rates up to December 31, 2024.
The amount of the fees based on the actual time spent is not necessarily the amount that will be billed to you, but may be adjusted based on the nature of the work performed or the results achieved. Each month before bills are issued, a review is performed to assess the nature and quality of the services performed for you. In cases where there is a significant disparity between the value of the services rendered or results achieved and the fees based on the time spent, the fees may be adjusted, as appropriate under the circumstances, to reflect that value.
In addition to our fees, Client will also be responsible for paying a 5% administrative charge calculated and based on fees billed to cover costs and expenses incurred in our handling of the matter such as photocopies, local travel charges and parking, fax charges, telephone charges and 468
A T K I N S O N , A N D E L SO N , L O Y A , RUUD & RO M O Angela C. Lopez, Executive Director HR
City of Ontario
June 12, 2024
50781055.1/005890.00001
other similar charges. In addition to the administrative charge Client will be responsible for reimbursing Firm for other out-of-pocket charges such as court and filing fees, deposition charges, messenger fees, witness fees, investigator fees and similar charges.
The Firm will not be obligated to advance costs on your behalf. However, for the purposes of convenience and in order to expedite matters, the Firm reserves the right to advance costs on your behalf with your prior approval in the event a particular cost item exceeds $2,000.00 in amount and without your prior approval in the event a particular cost item totals $2,000.00 or less.
The Firm will prepare a monthly statement containing a detailed description of the services performed and the costs advanced by the Firm during each month and will mail such statement to you on or about the 15th of the following month. Payment of the full amount due, as reflected on the monthly statement, will be due from you to the Firm by the end of that following month, unless other arrangements are made. In the event where you have funds deposited in the Firm’s Client Trust Account at the time a monthly billing statement is prepared, funds will be transferred from the Firm’s Client Trust Account to the Firm’s General Account to the extent of the balance due on the monthly statement and a credit for such payment will be reflected on the monthly statement.
Any balance of fees or costs advanced remaining unpaid after the due date will be subject to a 1% per month service charge.
Client agrees to review the Firm’s monthly statements promptly upon receipt and to notify the Firm, in writing, with respect to any disagreement with the monthly statement. Failure to communicate written disagreement with the Firm’s monthly statement within sixty (60) days of Client’s receipt thereof shall be deemed to signify Client’s agreement that the monthly billing statement accurately reflects: (i) the legal services performed; and (ii) the proper charge for those legal services.
Initial Deposit to be Applied to Fees and Costs Incurred. When the Firm accepts new clients or material for new matters from existing clients, our policy is to request a deposit against the fees and costs expected to be incurred in the first couple months after the Firm is engaged. This is a refundable deposit; any amount not owed for fees and costs incurred will be refunded upon request.
There is no fee deposit due at this time, but the Firm reserves the right to request refundable deposits at appropriate intervals during the Firm’s representation of you. All deposits will be placed in the Firm’s Client Trust Account. You hereby authorize the Firm to withdraw funds held in the Client Trust Account from time to time as fees and costs are incurred.
Conflicts with Other Clients. The Firm has a number of attorneys. The Firm may currently or in the future represent one or more other clients in matters involving Client. The Firm undertakes this engagement on the condition that the Firm may represent another client in a matter in which the Firm does not represent Client, even if the interests of the other client are adverse to those of Client (including appearance on behalf of another client adverse to Client in litigation or arbitration), provided the other matter is not substantially related to the Firm’s representation of 50781055.1/005890.00001
469
A T K I N S O N , A N D E L SO N , L O Y A , RUUD & RO M O Angela C. Lopez, Executive Director HR
City of Ontario
June 12, 2024
50781055.1/005890.00001
Client and in the course of representing Client attorneys of the Firm have not obtained confidential information of Client material to the representation of the other client (“Permitted Adverse Representation”). Client’s consent to this arrangement is required because of its possible adverse effects on performance of the Firm’s duties as attorneys to remain loyal and available to those other clients and to render legal services with vigor and competence. Also, if an attorney does not continue an engagement or must withdraw therefrom, the client may incur delay, prejudice or additional cost such as acquainting new counsel for the matter. Client agrees not to seek to disqualify the Firm from representing such other client in any Permitted Adverse Representation.
Termination of Representation. You may terminate this representation at any time, subject to the payment of any fees and costs incurred prior to such termination. The Firm may withdraw from this representation for good cause, on reasonable notice, without your consent. Good cause includes but is not limited to: (1) your failure to cooperate with us as provided above; (2) your failure to pay any bill when due or to replenish the deposit when requested as provided above; or (3) any fact or circumstance that would render our continuing representation unlawful or unethical.
Any termination of our representation of you would be subject to such approval as may be required from any court in which the Firm is appearing on your behalf.
Binding Agreement. This letter represents the entire agreement between you and the Firm with respect to this Matter and any other matter which we agree to perform on your request unless such matter is covered by a separate written agreement between you and us. By signing below, you acknowledge that you have carefully reviewed and understand the content of this letter and agree to be bound by all of its terms and conditions. Furthermore, you acknowledge that the Firm has made no representations or guarantees to you regarding the outcome, or the time necessary to resolve, the Matter. No change or waiver of any of the provisions of this letter will be binding on either you or the Firm unless the change is in writing and signed by both you and the Firm.
Document Retention Policy. The Firm will retain its files on each matter handled for you for five (5) years after the Matter is closed. The Firm will then destroy those files unless you have previously asked the Firm in writing to deliver those files to you. However, the Firm will not destroy the following types of files without giving thirty days’ written notice to you: (1) estate and succession planning files and (2) corporate, limited liability company or partnership organization and records files.
Consent to Firm Communication. As a part of the Firm's commitment to client service, we will send you periodic alerts on case developments and legislative changes. In addition, we will send you notice on Breakfast Briefings, Conferences, and other training opportunities designed to help you with your daily legal concerns. The Firm will send these and other additional service notices to you via regular mail and/or electronic mail at the e-mail address which you designate on the Technology Questionnaire, contract, or use in your daily communications with us. We believe that these e-mail notices are a quick and convenient way for us to keep you apprised of legal changes which affect your business.
470
A T K I N S O N , A N D E L SO N , L O Y A , RUUD & RO M O Angela C. Lopez, Executive Director HR
City of Ontario
June 12, 2024
50781055.1/005890.00001
Termination of Attorney-Client Relationship. The attorney-client relationship between you and the Firm will cease at the conclusion of the Matter. There are instances when the Firm has been engaged to provide ongoing general business, tax and estate planning advice to clients. If the Firm is not asked by the Client to provide advice for a period of one (1) year from the last date the Firm provided such ongoing advice, both you and the Firm agree that the attorney-client relationship is terminated on the last date the Firm provided advice, without further action or notice by either party. All other terms and conditions of this letter will remain in full force and effect, including the obligation to pay all unpaid fees and costs and the obligation to arbitrate any disputes as provided below. If you request additional legal services and the Firm agrees to perform those services after such termination, the terms and conditions of this letter will apply with respect to such services unless you and the Firm enter into a new written engagement agreement with respect to such services.
Attorneys’ Lien. Client grants the Firm a lien for all amounts owed to the Firm on any sum or sums recovered (whether by litigation, arbitration, settlement or otherwise) in connection with our representation of Client. The Firm is authorized by Client to use this lien to satisfy any obligation owed to the Firm by Client under this letter agreement. The lien will attach to any recovery Client may obtain, whether by arbitration, award, judgment, settlement or otherwise. The effect of such a lien is that the Firm may be able to compel payment of fees and costs from any such funds even if the Firm’s representation of Client has been terminated before the conclusion of the Matter.
Because the lien may affect Client’s property rights, it may be desirable for Client to seek the advice of an independent attorney before agreeing to such a lien. Irrespective of whether or not Client seeks such independent advice, the lien will be effective upon Client’s signing of this letter agreement.
Binding Arbitration. If any dispute arises out of, or related to, a claimed breach of this agreement, the professional services rendered by attorneys, or any other disagreement of any nature, type, or description, regardless of the facts or the legal theories which may be involved, including attorney malpractice, breach of fiduciary duty, misrepresentation, or conflict of interest, such dispute shall be resolved by confidential and binding arbitration upon the written request of one party after service of that request on the other party.
There are significant advantages and disadvantages of binding arbitration. The parties shall agree on an arbitrator with special skills and experience to hear and determine the dispute unlike in a court proceeding where a judge is assigned. If the parties cannot agree, then the Superior Court of Los Angeles County shall choose an impartial arbitrator whose decision shall be final and conclusive on all matters.
The parties shall each have the right of discovery in accordance with Code of Civil Procedure Section 1283. Arbitrations conducted pursuant to this agreement permit the same discovery rights as in a court proceeding. Each party shall bear their own costs and attorney fees, including payments to the arbitrator which can be significantly more costly than the filing fee in Court 471
A T K I N S O N , A N D E L SO N , L O Y A , RUUD & RO M O Angela C. Lopez, Executive Director HR
City of Ontario
June 12, 2024
50781055.1/005890.00001
proceedings where costs may be awarded to the prevailing party. Each party to this agreement waives and therefore gives up important constitutional rights in arbitration as the arbitrator’s decision is final. There is no right to appeal to challenge any errors made in the arbitration proceeding. Unlike court proceedings, arbitration proceedings are conducted privately and the outcome will remain confidential. There is no right to a trial by a judge or jury of one’s peers.
There is no limitation on the type of monetary damage that can be awarded by the arbitrator. The client is advised that the client has the right to have an independent lawyer of client’s choice review this arbitration provision.
If the above accurately reflects our mutual agreement, please confirm that by signing and returning a copy of this letter to me. Please do not hesitate to call me to discuss any questions you may have regarding this agreement. In addition, you have the right to consult other counsel to resolve your concerns. In conformance with the Firm’s policy, we cannot commence work upon this engagement until we have received a copy of this letter countersigned by you.
Thank you for giving us the opportunity to assist you with your legal matters. We look forward to working with you on this Matter.
Very truly yours,
ATKINSON, ANDELSON, LOYA, RUUD & ROMO
John H. Bakhit
JHB:jag
ACCEPTANCE AND CONSENT BY CLIENT
The undersigned is the Client or an authorized officer or agent of Client and has reviewed and hereby agrees and consents to the above terms and conditions of Client’s engagement of the Firm.
CITY OF ONTARIO
By:
Name: Angela C. Lopez
Title: Executive Director Human Resources/Risk Management 472
46700.00100\40935195.1
BB&K (2023) Exhibit “B”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "B"
SCHEDULE OF SERVICES
City will engage Consultant to render professional services for the City on an as-needed basis as set forth in this Agreement. Upon completion of services, the consultant shall bill the City monthly.
473
Department: Public Works
Prepared By: Tim Masot
Staff Member Presenting: Tito Haes, Executive
Director Public Works
Reviewed By: Gina Gomez, Bonnie Tam
Approved By:
Submitted To: Council/OHA
Approved: _______________________________
Continued To: ___________________________
Denied: __________________________________
Item No: 14
SUBJECT: A CONSTRUCTION CONTRACT WITH CT&T CONCRETE PAVING, INC. FOR
AMERICANS WITH DISABILITIES ACT (ADA) CONCRETE RAMP CONSTRUCTION
SERVICES
CITY OF ONTARIO
Agenda Report
July 16, 2024
SECTION:
CONSENT CALENDAR
RECOMMENDATION: That the City Council authorize the City Manager, or his designee, to execute a one-year Construction Contract with CT&T Concrete Paving, Inc., of Diamond Bar, California, for ADA Concrete Ramp Construction Services for a total not-to-exceed contract amount of $175,000.
THE FOLLOWING COUNCIL GOALS ARE BEING ACHIEVED:
Invest in the City's Infrastructure (Water, Streets, Sewers, Parks, Storm Drains and Public Facilities)
FISCAL IMPACT: The Fiscal Year 2024-25 Adopted Budget includes appropriations in the Community Development Block Grant (CDBG) Fund for ADA Concrete Ramp Construction Services.
The recommended Construction Contract with CT&T Concrete Paving, Inc., is for a total not-toexceed contract amount of $175,000.
BACKGROUND & ANALYSIS: The Public Works Agency is responsible for the maintenance and installation of ADA ramps citywide. Every year, an average of 25 to 30 new ADA ramps are installed throughout the City using a construction contract vendor. In June 2024, the City solicited bids for Bid No. 1801 ADA Concrete Ramps Construction Services. Six (6) bids were received, and all of them met the minimum bid criteria and standards necessary to perform the scope of work. A summary of the bid results are as follows:
Vendor Location
Bid Unit Price (Per
Ramp)
Total Bid Unit Price
with
Additional Services
CT&T Concrete Paving,
Inc.
Diamond Bar, CA $5,700 $13,367
Metrocell Construction,
Inc.
Ontario, CA $19,000 $49,209
474
MAJ Engineering Chino Hills, CA $140,000 $154,035
Garcon Construction Ontario, CA $104,000 $184,977
HZS Engineering and
Construction
Orange, CA $187,000 $208,075
Gentry General
Engineering, Inc.
Colton, CA $215,420 $225,174
CT&T Concrete Paving, Inc., of Diamond Bar, California, submitted the lowest responsible bid that met all the local and federal required specifications for a unit price of $5,700 per ramp and a total unit price of $13,367 per ramp with the different types of additional services. Additional services would be charged per ramp only when rock curb, Portland Cement Concrete (PCC) curb, or drive approach is removed and replaced. A one-time mobilization cost of $7,000 will be charged for the establishment of construction sites. Based on their credentials, pricing, and favorable reference checks, Staff recommends awarding the construction contract to CT&T Concrete Paving, Inc. 475
CDBG ADA Concrete Ramps Construction SM 2425-7 -1-
SECTION 00500 – CONTRACT FOR CONSTRUCTION
This Contract for Construction (“Contract”), No. ________ is made and entered as of ____________, by and between City of Ontario, with its principal place of business at 303 East “B” Street, Ontario, CA 91764, sometimes hereinafter called the “City” and CT& T Concrete Paving, Inc. sometimes hereinafter called “Contractor.” WITNESSETH: That the parties hereto have mutually covenanted and agreed, and by these presents do covenant and agree with each other as follows:
ARTICLE 1. SCOPE OF WORK.
The Contractor shall perform all Work within the time stipulated in the Contract, and shall provide all labor, materials, equipment, tools, utility services, and transportation to complete all of the Work required in strict compliance with the Contract Documents as specified in Article 5, below, for the following Project:
CDBG ADA Concrete Ramps Construction SM 2425-7.
Contractor is an independent contractor and not an agent of the City. The Contractor and its surety shall be liable to the City for any damages arising as a result of the Contractor’s failure to comply with this obligation.
ARTICLE 2. TIME FOR COMPLETION.
Time is of the essence in the performance of the Work. The Work shall be commenced on the date stated in the City’s Notice to Proceed. The Contractor shall complete all Work required by the Contract Documents within 365 calendar days from the commencement date stated in the Notice to Proceed. By its signature hereunder, Contractor agrees the time for completion set forth above is adequate and reasonable to complete the Work.
ARTICLE 3. CONTRACT PRICE.
The City shall pay to the Contractor as full compensation for the performance of the Contract, subject to any additions or deductions as provided in the Contract Documents, and including all applicable taxes and costs, the sum of One Hundred Seventy-Five Thousand Dollars with Zero Cents ($175,000). Payment shall be made as set forth in the General Conditions. The City will pay to Contractor compensation based upon the prices set forth in the Bid Schedule.
ARTICLE 4. LIQUIDATED DAMAGES.
Contractor acknowledges that the City will sustain actual damages for each and every Day completion of the Project is delayed beyond the Contract Time. Because of the nature of the SECTION 00500 – CONTRACT FOR
CONSTRUCTION
476
CDBG ADA Concrete Ramps Construction SM 2425-7 -2-
SECTION 00500 – CONTRACT FOR
CONSTRUCTION
Project, it would be impracticable or extremely difficult to determine the City’s actual damages.
Accordingly, in accordance with Government Code section 53069.85, it is agreed that the Contractor will pay the City the sum of $250 for each and every calendar day of delay beyond the time prescribed in the Contract Documents for finishing the Work, as Liquidated Damages and not as a penalty or forfeiture. In the event this is not paid, the Contractor agrees the City may deduct that amount from any money due or that may become due the Contractor under the Contract. This Section does not exclude recovery of other damages specified in the Contract Documents. Liquidated damages may be deducted from progress payments due Contractor, Project retention or may be collected directly from Contractor, or from Contractor's surety. These provisions for liquidated damages shall not prevent the City, in case of Contractor's default, from terminating the Contractor.
Consistent with Public Contract Code Section 7102, Contractor will be compensated for damages incurred due to delays for which the City is responsible. The parties agree that determining Contractor’s exact delay damages is and will continue to be impracticable and extremely difficult.
As such, for each calendar day in excess of the Contract Time, the City shall pay to the Contractor $250 per day as Reverse Liquidated Damages and not as a penalty or forfeiture. Such amount shall constitute the only payment allowed for any City caused delays and shall necessarily include all overhead, all profits, all administrative costs, all bond costs, all labor, materials, equipment and rental costs and any other costs, expenses and fees incurred or sustained as a result of such delays. Notice of requests for delay damages and additional days shall be provided to the City within five (5) Days from the discovery of the circumstances giving rise to any delay or three (3) Days from the discovery of any latent or subsurface conditions giving rise to a delay.
ARTICLE 5. COMPONENT PARTS OF THE CONTRACT.
The “Contract Documents” include the following
Notice Inviting Bids
Instructions to Bidders
Bid Forms
Bid Acknowledgement
Bid Schedule
Bid Guarantee
Designation of Subcontractors
Information Required of Bidders
Non-Collusion Declaration Form
Iran Contracting Act Certification
Public Works Contractor DIR Registration Certification
Performance Bond
Payment (Labor and Materials) Bond
Contract for Construction
General Conditions
Special Conditions
Specifications
Addenda
Construction Plans and Drawings
Standard Specifications for Public Works Construction “Greenbook”, latest edition, Except Sections 1-9
Applicable Local Agency Standards and Specifications, as last revised 477
CDBG ADA Concrete Ramps Construction SM 2425-7 -3-
SECTION 00500 – CONTRACT FOR
CONSTRUCTION
Reference Specifications
Approved and fully executed Change Orders
Permits
Any other documents contained in or incorporated into the Contract The Contractor shall complete the Work in strict accordance with all of the Contract Documents.
All of the Contract Documents are intended to be complementary. Work required by one of the Contract Documents and not by others shall be done as if required by all. In the event of conflict, the various Contract Documents will be given effect in the order set forth in the General Conditions. This Contract shall supersede any prior agreement of the parties.
ARTICLE 6. PROVISIONS REQUIRED BY LAW AND CONTRACTOR COMPLIANCE.
Each and every provision of law required to be included in these Contract Documents shall be deemed to be included in these Contract Documents. The Contractor shall comply with all requirements of applicable federal, state and local laws, rules and regulations, including, but not limited to, the provisions of the California Labor Code and California Public Contract Code which are applicable to this Work.
ARTICLE 7. INDEMNIFICATION.
Contractor shall provide indemnification and defense as set forth in the General Conditions.
ARTICLE 8. PREVAILING WAGES.
Contractor shall be required to pay the prevailing rate of wages in accordance with the Labor Code which such rates shall be made available at the City’s Office or may be obtained online at http://www.dir.ca.gov and which must be posted at the job site.
ARTICLE 9. FALSE CLAIMS.
Contractor acknowledges that if a false claim is submitted to the City, it may be considered fraud and Contractor may be subject to criminal prosecution. Contractor acknowledges that the False Claims Act, California Government Code sections 12650, et seq., provides for civil penalties where a person knowingly submits a false claim to a public entity. These provisions include within their scope false claims made with deliberate ignorance of the false information or in reckless disregard of the truth or falsity of the information. In the event the City seeks to recover penalties pursuant to the False Claims Act, it is entitled to recover its litigation costs, including attorneys’ fees. Contractor hereby acknowledges that the filing of a false claim may the Contractor to an administrative debarment proceeding wherein Contractor may be prevented from further bidding on public contracts for a period of up to five (5) years. [REMAINDER OF PAGE LEFT INTENTIONALLY BLANK]
478
CDBG ADA Concrete Ramps Construction SM 2425-7 -4-
SECTION 00500 – CONTRACT FOR
CONSTRUCTION
IN WITNESS WHEREOF, this Contract has been duly executed by the above-named parties, on the day and year above written.
CITY OF ONTARIO
By:
Scott Ochoa
City Manager
ATTEST:
By:
Sheila Mautz, City Clerk
APPROVED AS TO FORM:
By:
Best Best & Krieger LLP
City Attorney
CT&T Concrete Paving, Inc.
By:
Its:
Printed Name:
By:
Its:
Printed Name:
____________________________________
Contractor’s License Number and
Classification
____________________________________
DIR Registration Number
(CONTRACTOR’S SIGNATURE MUST BE
NOTARIZED AND CORPORATE SEAL
AFFIXED, IF APPLICABLE)
END OF CONTRACT
479
City of Ontario
CDBG ADA Concrete Ramps Construction SM 2425-7 (1801), bidding on 06/07/2024 3:00 PM (PDT)
Printed 06/20/2024
PlanetBids
480
City of Ontario
CDBG ADA Concrete Ramps Construction SM 2425-7 (1801), bidding on 06/07/2024 3:00 PM (PDT)
Printed 06/20/2024
PlanetBids
481
City of Ontario
CDBG ADA Concrete Ramps Construction SM 2425-7 (1801), bidding on 06/07/2024 3:00 PM (PDT)
Printed 06/20/2024
PlanetBids
482
Department: Public Works
Prepared By: Adrian Escamilla
Staff Member Presenting: Tito Haes, Executive
Director Public Works
Reviewed By: Andrea Ampig, Bonnie Tam
Approved By:
Submitted To: Council/OHA
Approved: _______________________________
Continued To: ___________________________
Denied: __________________________________
Item No: 15
SUBJECT: DESIGN SERVICES AGREEMENTS FOR ON-CALL RETAIL ARCHITECTURAL DESIGN
SERVICES
CITY OF ONTARIO
Agenda Report
July 16, 2024
SECTION:
CONSENT CALENDAR
RECOMMENDATION: That the City Council take the following action:
A. Authorize the City Manager, or his designee, to execute the following three-year Design Services Agreements for on-call Retail Architectural Services for a total compensation amount of $1,050,000 over three (3) years and extend the agreements for up to two (2) additional one-year periods:
1. Architecture Plus, Inc., of La Canada, California, for a total contract amount not-toexceed $150,000, and
2. DLR Group, of Riverside, California, for a total contract amount not-to-exceed $150,000, and
3. KWWA Architecture, of El Monte, California, for a total contract amount not-to-exceed $150,000, and
4. M. Arthur Genster Jr. & Associates, Inc., of Los Angeles, California, for a total contract amount not-to-exceed $150,000, and
5. Miller Architectural Corporation, of Riverside, California, for a total contract amount not-to-exceed $150,000, and
6. RDC-S111, Inc., of Long Beach, California, for a total contract amount not-to-exceed $150,000; and
7. Westgroup Designs, of Irvine, California, for a total contract amount not-to-exceed $150,000.
THE FOLLOWING COUNCIL GOALS ARE BEING ACHIEVED:
Operate in a Businesslike Manner
Invest in the City's Infrastructure (Water, Streets, Sewers, Parks, Storm Drains and Public Facilities)
Invest in the Growth and Evolution of the City's Economy 483
FISCAL IMPACT: The proposed Design Services Agreements with Architecture Plus, Inc., DLR Group, KWWA Architecture, M. Arthur Genster Jr. & Associate, Inc., Miller Architectural Corporation, RDCS111, Inc., and Westgroup Designs are an estimated amount of $50,000 per year for a total not-toexceed contract amount of $150,000 over three (3) years per contract.
All seven firms have agreed to fixed billing rates set forth in their respective agreements on an oncall, as needed basis for three years. Pricing for the option years will be negotiated and any proposed fee increases will not exceed 3% per year. The Fiscal Year 2024-25 Adopted Budget includes appropriations in the Capital Projects Fund, Capital Projects-Measure Q Fund, and General Fund for on-call Retail Architecture Services.
BACKGROUND & ANALYSIS: The City has needs for On-Call Retail Architectural Services for work that cannot be provided by City Staff. Staff is recommending contracts with a total of seven (7) qualified firms to assure a timely and cost-effective option is always available for each task order.
Additionally, Staff is recommending that all contracts be executed between the firms and the City, so that any City agencies can use these firms. This procedure reduces overhead charges and increases efficiency in completing critical projects, ultimately resulting in well-executed projects.
On May 15, 2024, the City solicited requests for qualifications for on-call Retail Architectural Services and responses from the following firms were evaluated:
Architectural Firm Location
Architecture Plus, Inc. La Canada, CA
DLR Group Riverside, CA
KWWA Architecture El Monte, CA
M. Arthur Gensler Jr. & Associates, Inc. Los Angeles, CA Miller Architectural Corporation Redlands, CA
RDC-S111, Inc. Long Beach, CA
Westgroup Designs Irvine, CA
City Staff reviewed the requests for proposals utilizing a qualifications-based selection process.
Architecture Plus, Inc., DLR Group, KWWA Architecture, M. Arthur Genster Jr. & Associates, Inc., RDCS111, Inc., Miller Architectural Corporation and Westgroup Designs were deemed to be the most qualified firms. The recommendation to award Design Services Agreements to these firms is based on their broad range of expertise as demonstrated by work performed for other municipal agencies and capability to perform highly complex work in a timely manner. 484
BB&K (2023)
46700.00100\40935196.1
-1-
CITY OF ONTARIO
DESIGN SERVICES AGREEMENT
1. PARTIES AND DATE.
This Agreement is made and entered into as of , by and between the City of Ontario, a municipal corporation organized and operating under the laws of the State of California with its principal place of business at 303 East “B” Street, Ontario, California 91764- 4196, County of San Bernardino, State of California (“City”), and M. Arthur Gensler Jr. & Associates, Inc a corporation with its principal place of business at 500 South Figueroa St. Los Angeles, CA 90071 (hereinafter referred to as “Consultant”). City and Consultant are sometimes individually referredto herein as “Party” and collectively as “Parties.”
2. RECITALS.
2.1 City. City is a municipal corporation organized under the laws of the State of California, with power to contract for services necessary to achieve its purpose.
2.2 Consultant. Consultant desires to perform and assume responsibility for the provision of certain professional architectural design services requiredby the City on the terms and conditions set forth in this Agreement. Consultant warrants that it isfully licensed, qualified, and willing to perform the services required by this Agreement; provided, however, that if Consultant is a corporation or other organization, the Project Consultant designated pursuant to Section 3.2, and not the Consultant itself, shall be fully licensed to practiceas an architect in the State of California.
2.3 Project. City desires to engage Consultant to render such services for the On-Call Retail Architect Design Services ("Project") as set forth in this Agreement.
3. TERMS
3.1 Employment of Consultant.
3.1.1 Scope of Services. Consultant promises and agrees to furnish to City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the professional architectural and related services necessary for the full and adequate completion of the Project consistent with the provisions of this Agreement 485
BB&K (2023)
46700.00100\40935196.1
-2-
(hereinafter referred to as “Services”). The Services are more particularly described throughout this Agreement, including Exhibit “A” attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordancewith, this Agreement, any exhibits attached hereto and incorporated herein by reference, and allapplicable local, state and federal laws, rules and regulations. All Services performed by Consultant shall be subject to the sole and discretionary approval of the City, which approval shallnot be unreasonably withheld.
3.1.2 Term. The term of this Agreement shall be from July 16, 2024, to July 16, 2027, The City shall have the unilateral option, at its sole discretion, to renew this Agreement automatically for no more than two additional one-year terms unless earlier terminated as provided herein. Consultant shall complete the Services within the term of agreement and shall meet any other established scheduled and deadlines.
3.2 Project Consultant; Key Personnel.
3.2.1 Retail Architect. Consultant shall name a specific individual to act as Project Consultant, subject to the approval of City. Consultanthereby designates Aaron Birney (License No. #C4622) to act as the Retail Architect for the Project. The Architect shall: (1) maintain oversight of the Services; (2) have full authority to represent and act on behalf of the Consultant for all purposes under thisAgreement; (3) supervise and direct the Services using his or her best skill and attention; (4) be responsible for the means, methods, techniques, sequences and procedures used for theServices; (5) adequately coordinate all portions of the Services; and (6) act as principal contact with y and all contractors, consultants, engineers and inspectors on the Project.
Any change in the Retail Architect shall be subject to the City’s prior written approval, which approval shall not be unreasonably withheld. The new Retail Architect shall be of at least equal competence as the prior Retail Architect. In the event that City and Consultant cannotagree as to the substitution of a new Retail Architect. City shall be entitled to terminate this Agreement for cause.
3.2.2 Key Personnel. In addition to the Retail Architect, Consultant has represented to the City that certain additional key personnel, engineers and consultants will perform the Services under this Agreement. Should one or more of such personnel, engineers or consultants become unavailable, Consultant may substitute others of atleast equal competence upon written approval of the City. In the event that City and Consultant cannot agree as to the substitution of key personnel, engineers or consultants, City shall be entitled to terminate this Agreement for cause. The key additional personnel, engineers and consultants for performance of this Agreement are as follows: Aaron Birney, Principal
3.3 Hiring of Consultants and Personnel.
3.3.1 Right to Hire or Employ. Consultant shall have the option, unless City objects in writing after notice, to employ at its expense architects, engineers, experts or other consultants qualified and licensed to render services in connection with the planning and/or administration of the Project, and to delegate to them such duties as Consultant may delegate without relieving Consultant from administrative or other responsibility under this Agreement.
Consultant shall be responsible for the coordination and cooperation of Consultant’s architects, engineers, experts or other consultants. All consultants, including changes in consultants, shall be subject to approval by City in its sole and reasonable discretion. Consultant shall notify City of the identity of all consultants at least fourteen (14) days prior to their commencement of work to allow City to review their qualifications and approve to their participation on the Project in its 486
BB&K (2023)
46700.00100\40935196.1
-3-
sole and reasonable discretion.
3.3.2 Qualification and License. All architects, engineers, experts and other consultants retained by Consultant in performance of this Agreement shall be qualified to perform the Services assigned to them, and shall be licensed to practice in their respective professions, where required by law.
3.3.3 Standards and Insurance. All architects, engineers, experts and other consultants hired by Consultant shall be required to meet all of the same standards and insurance requirements set forth in this Agreement, unless other standards or requirements are approved by the City in writing. Unless changes are approved in writing by the City, Consultant’s agreements with its consultants shall contain a provision making them subject to all provisions stipulated in this Agreement.
3.3.4 Assignments or Staff Changes. Consultant shall promptly obtain written City approval of any assignment, reassignment or replacement of such architects, engineers, experts and consultants, or of other staff changes of key personnel working on the Project. As provided in the Agreement, any changes in Consultant’s consultants and key personnel shall be subject to approval by City.
3.3.5 Draftsman and Clerical Support. Draftsmen and clerical personnel shall be retained by Consultant at Consultant’s sole expense.
3.4 Standard of Care.
3.4.1 Standard of Care. Consultant shall perform all Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals qualified to perform the Services in the same discipline in the State of California, and shall be responsible to City for damages sustained by the City and delays to the Project as specified in the indemnification provision of this Agreement. Without limiting the foregoing, Consultant shall be fully responsible to the City for any increased costs incurred by the City as a result of any such delays in the design or construction of the Project. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services. Consultant warrants and represents that all of its employees, architects, engineers, experts and other consultants shall have sufficient skill and experience to perform the Services assigned to them. Finally, Consultant represents that it, its employees, architects, engineers, experts and other consultants have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services assigned to or rendered by them and that such licenses and approvals shall be maintained throughout the term of this Agreement. As provided for in the indemnification provisions of this Agreement, Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant’s failure to comply with the standard of care provided for herein.
3.4.2 Performance of Employees. Any employee or consultant who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee or consultant who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed from the Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.
487
BB&K (2023)
46700.00100\40935196.1
-4-
3.5 Laws and Regulations.
3.5.1 Knowledge and Compliance. Consultant shall keep itself fully informed of and in compliance with all applicable local, state and federal laws, rules and regulations in any manner affecting the performance of the Services or the Project, and shall give all notices required of the Consultant by law. Consultant shall be liable, pursuant to the standard of care and indemnification provisions of this Agreement, for all violations of such laws and regulations in connection with its Services. Consultant shall defend, indemnify and hold City, its officials, officers, employees and agents free and harmless, pursuant to the indemnification provisions of this Agreement, from any claim or liability arising out of any failure or alleged failure to comply with such laws, rules or regulations.
3.5.2 Drawings and Specifications. Consultant shall cause all drawings and specifications to conform to any applicable requirements of federal, state and local laws, rules and regulations, including the Uniform Building Code, in effect as of the time the drawings and specifications are prepared or revised during the latest phase of the Services described in Exhibit “A” attached hereto. Any significant revisions made necessary by changes in such laws, rules and regulations after this time may be compensated as Additional Services which were not knownor reasonably should not have been known by Consultant. Consultant shall cause the necessary copies of such drawings and specifications to be filed with any governmental bodies with approval jurisdiction over the Project, in accordance with the Services described in Exhibit “A” attached hereto. For the preparation of all such drawings and specifications, the Consultant shall use Computer Aided Design Drafting (“CADD”) (e.g., AutoCAD) or other technology acceptable to the Consultant and City.
3.5.3 Americans with Disabilities Act. Consultant will use its best professional efforts to interpret all applicable federal, state and local laws, rules and regulations with respect to access, including those of the Americans with Disabilities Act (“ADA”). Consultant shall inform City of the existence of inconsistencies of which it is aware or reasonably should be aware between federal and state accessibility laws, rules and regulations, as well as any other issues which are subject to conflicting interpretations of the law, and shall provide the City with its interpretation of such inconsistencies and conflicting interpretations. Unless Consultant brings such inconsistencies and conflicting interpretations to the attention of the City and requests City’s direction on how to proceed, the Consultant’s interpretation of such inconsistencies and conflicting interpretations shall be the sole responsibility and liability of Consultant, and the Consultant shall correct all plans, specifications and other documents prepared for the Project at no additional cost if its interpretations are shown to be incorrect. In the event that the Consultant request’s City’s direction on how to proceed with respect to any inconsistent and/or conflicting interpretation, the Consultant shall be responsible to the City only pursuant to the indemnification provisions of this Agreement.
3.5.4 Permits, Approvals and Authorizations. Consultant shall provide City with a list of all permits, approvals or other authorizations required for the Project from all federal, stateor local governmental bodies with approval jurisdiction over the Project. Consultant shall then assist the City in obtaining all such permits, approvals and other authorizations. The costs of such permits, approvals and other authorizations shall be paid by the City.
3.5.5 Water Quality Management and Compliance. Consultant shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Services including, without limitation, all applicable provisions of the City’s ordinances 488
BB&K (2023)
46700.00100\40935196.1
-5-
regulating water quality and storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251 et seq.); the California Porter-Cologne Water Quality Control Act (Cal Water Code §§ 13000- 14950); and any and all regulations, policies, or permits issued pursuant to any such authority.
Consultant shall additionally comply with the lawful requirements of the City, and any other municipality, drainage district, or other local agency with jurisdiction over the location where the Services are to be conducted, regulating water quality and storm water discharges. Failure to comply with laws, regulations, and ordinances listed in this Section is a violation of federal and state law.
3.6 Independent Contractor.
3.6.1 Control and Payment of Subordinates. City retains Consultant on an independent contractor basis and Consultant is not an employee of City. Consultant is not an employee for state tax, federal tax or any other purpose, and is not entitled to the rights or benefits afforded to City’s employees. Any additional personnel performing the Services under this Agreement on behalf of Consultant shall also not be employees of City, and shall at all times be under Consultant’s exclusive direction and control. Consultant shall pay all wages, salaries, and other amounts due such personnel in connection with their performance of Services under this Agreement and as required by law. Consultant shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers’ compensation insurance.
3.7 Schedule of Services.
3.7.1 Consultant Services. Consultant shall fully and adequately complete the Services described in this Agreement and in Exhibit “A” attached hereto and incorporated herein by reference.
3.7.2 Timely Performance Standard. Consultant shall perform all Services hereunder as expeditiously as is consistent with professional skill and care, as well as the orderly progress of the Project work so as not to be the cause, in whole or in part, of delays in the completion of the Project or in the achievement of any Project milestones, as provided herein.
Specifically, Consultant shall perform its Services so as to allow for the full and adequate completion of the Project within the time required by the City and within any completion schedules adopted for the Project. Consultant agrees to coordinate with City’s staff, contractors and consultants in the performance of the Services, and shall be available to City’s staff, contractors and consultants at all reasonable times.
3.7.3 Performance Schedule. Consultant shall prepare an estimated time schedule for the performance of Consultant’s Services, to be adjusted as the Project proceeds.
Such schedule shall be subject to the City’s review and approval, which approval shall not be unreasonably withheld, and shall include allowances for periods of time required for City’s review and approval of submissions, and for approvals of authorities having jurisdiction over Project approval and funding. If City and Consultant cannot mutually agree on a performance schedule, City shall have the authority to immediately terminate this Agreement. The schedule shall not be exceeded by Consultant without the prior written approval of City. If the Consultant’s Services are not completed within the time provided by the agreed upon performance schedule, or any milestones established therein, it is understood, acknowledged and agreed that the City will suffer damage for which the Consultant will be responsible.
489
BB&K (2023)
46700.00100\40935196.1
-6-
3.7.4 Excusable Delays. Any delays in Consultant’s work caused by the following may be added to the time for completion of any obligations of Consultant: (1) the actionsof City or its employees; (2) the actions of those in direct contractual relationship with City; (3) theactions of any governmental agency having jurisdiction over the Project; (4) the actions of any parties not within the reasonable control of the Consultant; and (5) any Force Majeure Event (asdefined herein) or other unforeseen occurrence not due to any fault or negligence on the part of Consultant. Neither the City nor the Consultant shall be liable for damages, liquidated or otherwise, to the other on account of such delays.
3.7.5 Force Majeure Events. Neither City nor Consultant shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the non-performing Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Consultant and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the Services and Agreement. Should a Force Majeure Event occur, the nonperforming Party shall, within fifteen (15) calendar days of the beginning of an Force Majeure Event, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events shall not entitle Consultant to any additional compensation. Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement.
3.7.6 Request for Excusable Delay Credit. The Consultant shall, within fifteen (15) calendar days of the beginning of any excusable delay, notify the City in writing of the causes of delay (unless City grants in writing a further period of time to file such notice prior to the date of final payment under the Agreement). City will then ascertain the facts and the extent of the delay, and grant an extension of time for completing the Services when, in its sole judgment, the findings of fact justify such an extension. The City’s findings of fact thereon shall be final and conclusive on the Parties. Extensions of time shall apply only to that portion of the Services affected by the delay and shall not apply to other portions of the Services not so affected. The sole remedy of Consultant for extensions of time shall be an extension of the performance time at no cost to the City. If Additional Services are required as a result of an excusable delay, the Parties shall mutually agree thereto pursuant to the Additional Services provision of this Agreement. Should Consultant make an application for an extension of time, Consultant shall submit evidence that the insurance policies required by this Agreement remain in effect during the requested additional period of time.
3.8 Additional Services.
3.8.1 Request for Services. At City’s request, Consultant may be asked to perform services not otherwise included in this Agreement, not included within the basic services listed in Exhibit “A” attached hereto, and/or not customarily furnished in accordance with generally 490
BB&K (2023)
46700.00100\40935196.1
-7-
accepted architectural practice.
3.8.2 Definition. As used herein, “Additional Services” mean: (1) any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary for the Consultant to perform at the execution of this Agreement; or (2) any work listed as Additional Services in Exhibit “A” attached hereto. Consultant shall not perform, nor be compensated for, Additional Services without prior written authorization from City and without an agreement between the City and Consultant as to the compensation to be paid for such services. City shall pay Consultant for any approved Additional Services, pursuant to the compensation provisions herein, so long as such services are not made necessary through the fault of Consultant pursuant to the indemnification provision of this Agreement.
3.8.3 Examples of Additional Services. Such Additional Services shall notinclude any redesign or revisions to drawings, specifications or other documents when such revisions are necessary in order to bring such documents into compliance with applicable laws, rules, regulations or codes of which Consultant was aware or should have been aware pursuantto the laws and regulations provision of this Agreement above. Such Additional Services may include, but shall not be limited to:
(a) Separately Bid Portions of Project. Plan preparation and/or administration of work on portions of the Project separately bid. (b) Furniture and Interior Design. Assistance to City, if requested, for the selection of moveable furniture, equipment or articles which are not included in the Construction Documents.
(c) Fault of Contractor. Services caused by delinquency, default or insolvency of contractor, or by major defects in the work of the contractor, provided that any such services made necessary by the failure of Consultant to detect and report such matters when it reasonably should have done so shall not be compensated. (d) Inconsistent Approvals or Instructions. Revisions in drawings, specifications or other documents when such revisions are inconsistent with written approvals or instructions previously given and are due to causes beyond the control of Consultant. (e) Legal Proceedings. Serving as an expert witness on City's behalf or attending legal proceedings to which the Consultant is not a party. (f) Damage Repair. Supervision of repair of damages to any structure. (g) Extra Environmental Services. Additional work required for environmental conditions (e.g. asbestos or site conditions) not already contemplated within the Consultant's services for the Project.
3.9 City Responsibilities. City’s responsibilities shall include the following:
3.9.1 Data and Information. City shall make available to Consultant all necessary data and information concerning the purpose and requirements of the Project, including scheduling and budget limitations, objectives, constraints and criteria. As part of the budget limitation information, the City shall provide the Consultant with a preliminary construction budget 491
BB&K (2023)
46700.00100\40935196.1
-8-
(“City’s Preliminary Construction Budget”).
3.9.2 Project Survey. If required pursuant to the scope of the Project and if requested by Consultant, City shall furnish Consultant with, or direct Consultant to procure at City’s expense, a survey of the Project site prepared by a registered surveyor or civil engineer, any other record documents which shall indicate existing structures, land features, improvements, sewer, water, gas, electrical and utility lines, topographical information and boundary dimensions of the site, and any other such pertinent information.
3.9.3 Bid Phase. Distribute Construction Documents to bidders and conduct the opening and review of bids for the Project.
3.9.4 Testing. Retain consultant(s) to conduct chemical, mechanical, soils, geological or other tests required for proper design of the Project, and furnish such surveys, borings, test pits, and other tests as may be necessary to reveal conditions of the site which must be known to determine soil condition or to ensure the proper development of the required drawings and specifications.
3.9.5 Required Inspections and Tests. Retain consultant(s) to conduct materials testing and inspection or environmental/hazardous materials testing and inspection pursuant to any applicable laws, rules or regulations.
3.9.6 Fees of Reviewing or Licensing Agencies. Directly pay or reimburse the payment of all fees required by any reviewing or licensing agency, or other agency having approval jurisdiction over the Project.
3.9.7 City’s Representative. The City hereby designates the City Manager, or his or her designee, to act as its representative for the performance of this Agreement (“City’s Representative”). City’s Representative shall have the power to act on behalf of the City for all purposes under this Contract. The City Manager hereby designates Tito Haes , Executive Director Public Works, or his or her designee, as the City’s contact for the implementation of the Services hereunder. Contractor shall not accept direction or orders from any person other than the City’s Representative or his or her designee.
3.9.8 Review and Approved Documents. Review all documents submitted by Consultant, including change orders and other matters requiring approval by the City Council or other officials. City shall advise Consultant of decisions pertaining to such documents within a reasonable time after submission, so as not to cause unreasonable delay as provided in the excusable delay provisions of this Agreement above.
3.10 Compensation.
3.10.1 Consultant’s Compensation for Basic Services. City shall pay to Consultant, for the performance of all Services rendered under this Agreement, the total not to exceed amount of One Hundred Fifty Thousand Dollars ($150,000) (“Total Compensation”).
This Total Compensation amount shall be based upon, and may be adjusted according to, the fee schedule and related terms and conditions attached hereto as Exhibit “B” and incorporated herein by reference. The Total Compensation, as may be adjusted upon mutual agreement, shall constitute complete and adequate payment for Services under thisAgreement.
3.10.2 Payment for Additional Services. At any time during the term of this Agreement, City may request that Consultant perform Additional Services. As used herein, 492
BB&K (2023)
46700.00100\40935196.1
-9-
Additional Services means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement. Any additional work in excess of this amount must be approved by the City. If authorized, such Additional Services will be compensated at the rates and in the manner set forth in Exhibit “B” attached hereto and incorporated herein by reference, unless a flat rate or some other form of compensation is mutually agreed upon by the Parties. IfCity requires Consultant to hire consultants to perform any Additional Services, Consultant shall be compensated therefore at the rates and in the manner set forth in Exhibit “B” attached heretoand incorporated herein by reference, unless a flat rate or some other form of compensation is mutually agreed upon by the Parties. City shall have the authority to review and approve the rates of any such consultants. In addition, Consultant shall be reimbursed for any expenses incurred by such consultants pursuant to the terms and conditions of Section 3.10.3.
3.10.3 Reimbursable Expenses. Reimbursable expenses are in addition to compensation for the Services and Additional Services. Consultant shall not be reimbursed for any expenses unless authorized in writing by City, which approval may be evidenced by inclusion in Exhibit “B” attached hereto. Such reimbursable expenses shall include only those expenses which are reasonably and necessarily incurred by Consultant in the interest of the Project.
Consultant shall be required to acquire prior written consent in order to obtain reimbursement for the following: (1) extraordinary transportation expenses incurred in connection with the Project; (2) out-of-town travel expenses incurred in connection with the Project; (3) fees paid for securing approval of authorities having jurisdiction over the Project; (4) bid document duplication costs in excess of $1,000; and (5) other costs, fees and expenses in excess of $1,000.
3.10.4 Payment to Consultant. Consultant’s compensation and reimbursable expenses shall be paid by City to Consultant no more often than monthly. Such periodic payments shall be made based upon the percentage of work completed, and in accordance with the phasing and funding schedule provided in Exhibit “B” and the compensation rates indicated in Exhibit “B” attached hereto and incorporated herein by reference. In order to receive payment, Consultant shall present to City an itemized statement which indicates Services performed, percentage of Services completed, method for computing the amount payable, and the amount to be paid. The statement shall describe the amount of Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement, as well as those expenses for which reimbursement is requested for that statement period. The amount paid to Consultant shall never exceed the percentage amounts authorized by the phasing and funding schedule located in Exhibit “B” attached hereto. City shall, within thirty (30) days of receiving such statement, review the statement and pay all approved charges thereon pursuant to the provisions of Civil Code Section 3320. Disputed amounts shall be resolved by the Parties in a mutually agreeable manner.
Payments made for Additional Services shall be made in installments, not more often than monthly, proportionate to the degree of completion of such services or in such other manner as the Parties shall specify when such services are agreed upon, and in accordance with any authorized fee or rate schedule. In order to receive payment, Consultant shall present to City an itemized statement which indicates the Additional Services performed, percentage of Additional Services completed, method for computing the amount payable, and the amount to be paid. The statement shall describe the amount of Additional Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement. City shall, within thirty (30) days of receiving such statement, review the statement and pay all approved charges thereon pursuant to the provisions of Civil Code Section 3320. Disputed amounts shall be resolved by the Parties in a mutually agreeable manner. 493
BB&K (2023)
46700.00100\40935196.1
-10-
Upon cancellation or termination of this Agreement, Consultant shall be compensated as set forth in the termination provision herein.
3.10.5 Withholding Payment to Consultant. The City may withhold payment, in whole or in part, to the extent reasonably necessary to protect the City from claims, demands, causes of action, costs, expenses, liabilities, losses, damages, or injuries of any kind to the extent arising out of or caused by the negligence, recklessness, or willful misconduct protected under the indemnification provisions of this Agreement. Failure by City to deduct any sums from a progress payment shall not constitute a waiver of the City’s right to such sums. The City may keep any moneys which would otherwise be payable at any time hereunder and apply the same,or so much as may be necessary therefor, to the payment of any expenses, losses, or damagesas determined by the City, incurred by the City for which Consultant is liable under the Agreementor state law. Payments to the Consultant for compensation and reimbursable expenses due shallnot be contingent on the construction, completion or ultimate success of the Project. Payment tothe Consultant shall not be withheld, postponed, or made contingent upon receipt by the City of offsetting reimbursement or credit from Parties not within the Consultant’s reasonable control.
3.10.6 Prevailing Wages. Consultant is aware of the requirements of California Labor Code Sections 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., (“Prevailing Wage Laws”), which require the payment of prevailing wage rates and the performance of other requirements on certain “public works” and “maintenance” projects. If the Services are being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and if the total compensation is $1,000 or more, Consultant agrees to fully complywith and to require its consultants to fully comply with such Prevailing Wage Laws. City shall provide Consultant with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Consultant shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services available to interested parties upon request, and shall post copies at the Consultant’s principal place of business and at the Project site. It shall be mandatory upon the Consultant and all subconsultants to comply with all California Labor Code provisions, which include but are not limited to prevailing wages (Labor Code Sections 1771, 1774 and 1775), employment of apprentices (Labor Code Section 1777.5), certified payroll records (Labor Code Sections 1771.4and 1776), hours of labor (Labor Code Sections 1813 and 1815) and debarment of contractors and subcontractors (Labor Code Section 1777.1). The requirement to submit certified payroll records directly to the Labor Commissioner under Labor Code section 1771.4 shall not apply to work performed on a public works project that is exempt pursuant to the small project exemption specified in Labor Code Section 1771.4. Consultant shall defend, indemnify and hold the City, itselected officials, officers, employees and agents free and harmless from any claims, liabilities, costs, penalties or interest arising out of any failure or alleged failure of the Consultant or its consultants to comply with the Prevailing Wage Laws. (a) Registration/DIR Compliance. If the Services are being performed as part of an applicable “public works project” of over $25,000 when the project is for construction, alteration, demolition, installation, or repair work, or a public works project of over $15,000 when the project is for maintenance work, in addition to the foregoing, then pursuant to Labor Code sections 1725.5 and 1771.1, the Consultant and all subconsultants performing such Services must be registered with the Department of Industrial Relations (“DIR”). Consultant shall maintain registration for the duration of the Project and require the same of any subconsultants. This project may also be subject to compliance monitoring and enforcement by the DIR. It shall be Consultant’s sole responsibility to comply with all applicable registration and labor compliance 494
BB&K (2023)
46700.00100\40935196.1
-11-
requirements, including the submission of payroll records directly to the DIR. Any stop orders issued by the Department of Industrial Relations against Consultant or any subconsultant that affect Consultant’s performance of services, including any delay, shall be Consultant’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Consultant caused delay and shall not be compensable by the City. Consultant shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the Department of Industrial Relations against Consultant or any subconsultant.
3.11 Notice to Proceed.
Consultant shall not proceed with performance of any Services under this Agreement unless and until the City provides a written notice to proceed.
3.12 Termination, Suspension and Abandonment.
3.12.1 Grounds for Termination; Consultant’s Termination for Cause. City hereby reserves the right to suspend or abandon, at any time and for any reason, all or any portion of the Project and the construction work thereon, or to terminate this Agreement at any time with or without cause. Consultant shall be provided with at least seven (7) days advanced written notice of such suspension, abandonment or termination. In the event of such suspension, abandonment or termination, Consultant shall be paid for Services and reimbursable expenses rendered up to the date of such suspension, abandonment or termination, pursuant to the schedule of payments provided for in this Agreement, less any claims against or damages suffered by City as a result of the default, if any, by Consultant. Consultant hereby expressly waives any and all claims for damages or compensation arising under this Agreement, except as set forth herein, in the event of such suspension, abandonment or termination. Consultant may terminate this Agreement for substantial breach of performance by the City such as failure to make payment to Consultant as provided in this Agreement.
3.12.2 City’s Suspension of Work. If Consultant’s Services are suspended by City, City may require Consultant to resume such Services within ninety (90) days after written notice from City. When the Project is resumed, the Total Compensation and schedule of Services shall be equitably adjusted upon mutual agreement of the City and Consultant.
3.12.3 Documents and Other Data. Upon suspension, abandonment or termination, Consultant shall provide to City all preliminary studies, sketches, working drawings, specifications, computations, and all other Project Documents, as defined below, to which City would have been entitled at the completion of Consultant’s Services under this Agreement. Upon payment of the amount required to be paid to Consultant pursuant to the termination provisions of this Agreement, City shall have the rights, as provided in this Agreement hereinafter, to use such Project Documents prepared by or on behalf of Consultant under this Agreement. Consultant shall make such documents available to City upon request and without additional compensation other than as may be approved as a reimbursable expense.
3.12.4 Employment of other Consultants. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated.
3.13 Ownership and Use of Documents; Confidentiality.
495
BB&K (2023)
46700.00100\40935196.1
-12-
3.13.1 Ownership. All plans, specifications, original or reproducibletransparencies of working drawings and master plans, preliminary sketches, architectural presentation drawings, structural computations, estimates and any other documents prepared pursuant to this Agreement, including, but not limited to, any other works of authorship fixed in any tangible medium of expression such as writings, physical drawings and data magnetically orotherwise recorded on computer diskettes (hereinafter referred to as the “Project Documents”) shall be and remain the property of City. Although the official copyright in all Project Documentsshall remain with the Consultant or other applicable subcontractors or consultants, the Project Documents shall be the property of City whether or not the work for which they were made is executed or completed. Within thirty (30) calendar days following completion of the Project, Consultant shall provide to City copies of all Project Documents required by City. In addition, Consultant shall retain copies of all Project Documents on file for a minimum of fifteen (15) years following completion of the Project, and shall make copies available to City upon the payment ofreasonable duplication costs. Before destroying the Project Documents following this retention period, Consultant shall make a reasonable effort to notify City and provide City with the opportunity to obtain the documents.
3.13.2 Right to Use. Consultant grants to City the right to use and reuse all or part of the Project Documents, at City’s sole discretion and with no additional compensation to Consultant, for the following purposes:
(a) The construction of all or part of this Project.
(b) The repair, renovation, modernization, replacement, reconstruction or expansion of this Project at any time;
(c) The construction of another project by or on behalf of the City for its ownership and use;
City is not bound by this Agreement to employ the services of Consultant in the event such documents are used or reused for these purposes. City shall be able to use or reuse the Project Documents for these purposes without risk of liability to the Consultant or third parties with respect to the condition of the Project Documents, and the use or reuse of the Project Documents for these purposes shall not be construed or interpreted to waive or limit City’s right to recover for latent defects or for errors or omissions of the Consultant.
Any use or reuse by City of the Project Documents on any project other than this Project without employing the services of Consultant shall be at City’s own risk with respect to third parties. If City uses or reuses the Project Documents on any project other than this Project, it shall remove the Consultant’s seal from the Project Documents and hold harmless Consultant and its officers, directors, agents and employees from claims arising out of the negligent use or re-use of the Project Documents on such other project.
3.13.3 License. This Agreement creates a non-exclusive and perpetual license for City to copy, use, modify or reuse any and all Project Documents and any intellectual property rights therein. Consultant shall require any and all subcontractors and consultants to agree in writing that City is granted a non-exclusive and perpetual license for the work of such subcontractors or consultants performed pursuant to this Agreement.
3.13.4 Right to License. Consultant represents and warrants that Consultant has the legal right to license any and all copyrights, designs and other intellectual property embodied 496
BB&K (2023)
46700.00100\40935196.1
-13-
in the Project Documents that Consultant prepares or causes to be prepared pursuant to this Agreement. Consultant shall indemnify and hold City harmless pursuant to the indemnification provisions of this Agreement for any breach of this Section. Consultant makes no such representation and warranty in regard to previously prepared designs, plans, specifications, studies, drawings, estimates or other documents that were prepared by design professionals other than Consultant and provided to Consultant by City.
3.13.5 Confidentiality. All Project Documents, either created by or provided to Consultant in connection with the performance of this Agreement, shall be held confidential by Consultant to the extent they are not subject to disclosure pursuant to the Public Records Act. All Project Documents shall not, without the written consent of City, be used or reproduced by Consultant for any purposes other than the performance of the Services. Consultant shall not disclose, cause or facilitate the disclosure of the Project Documents to any person or entity not connected with the performance of the Services or the Project. Nothing furnished to Consultant which is otherwise known to Consultant or is generally known, or has become known, to the related industry shall be deemed confidential. Consultant shall not use City’s name or insignia, photographs of the Project, or any publicity pertaining to the Services or the Project in any magazine, trade paper, newspaper, television or radio production or other similar medium without the written consent of City.
3.14 Indemnification.
3.14.1 To the fullest extent permitted by law, Consultant shall defend (with counsel of City’s choosing), indemnify and hold the City, its officials, officers, employees, volunteers, and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Consultant, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Consultant’s Services, the Project or this Agreement, including without limitation the payment of all damages, expert witness fees and attorney’s fees and other related costs and expenses except such loss or damage caused by the sole negligence or willful misconduct of the City. Consultant's obligation to indemnify shall survive expiration or termination of this Agreement and shall not be restricted to insurance proceeds, if any, received by Consultant, the City, its officials, officers, employees, agents, or volunteers.
3.14.2 If Consultant’s obligation to defend, indemnify, and/or hold harmless arises out of Consultant’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Consultant’s indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Consultant, and, upon Consultant obtaining a final adjudication by a court of competent jurisdiction, Consultant’s liability for such claim, including the cost to defend, shall not exceed the Consultant’s proportionate percentage of fault.
3.15 Insurance. Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this Section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurancerequired under this section.
497
BB&K (2023)
46700.00100\40935196.1
-14-
3.15.1 Types of Insurance Required. As a condition precedent to the effectiveness of this Agreement for work to be performed hereunder, and without limiting the indemnity provisions of the Agreement, Consultant shall, at its expense, procure and maintain infull force and effect for the duration of the Agreement the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Consultant agrees to amend, supplement or endorse the policies to do so.
3.15.2 Additional Insured. The City of Ontario, its officials, officers, employees, agents, and volunteers shall be named as additional insureds on Consultant’s and its subconsultants’ policies of commercial general liability and automobile liability insurance using the endorsements and forms specified herein or exact equivalents.
3.15.3 Commercial General Liability
(a) The Consultant shall take out and maintain, during the performance of all work under this Agreement, in amounts not less than specified herein, Commercial General Liability Insurance, in a form and with insurance companies acceptable to the City. (b) Coverage for Commercial General Liability insurance shall be at least as broad as the following: Insurance Services Office Commercial General Liability coverage (Occurrence Form CG 00 01) or exact equivalent. Commercial General Liability Insurance must include coverage for the following:
(i) Bodily Injury and Property Damage
(ii) Personal Injury/Advertising Injury
(iii) Premises/Operations Liability
(iv) Products/Completed Operations Liability
(v) Aggregate Limits that Apply per Project
(vi) Explosion, Collapse and Underground (UCX) exclusion deleted
(vii) Contractual Liability with respect to this Contract (viii) Broad Form Property Damage
(ix) Independent Consultants Coverage
(c) The policy shall contain no endorsements or provisions limiting coverage for (1) contractual liability; (2) cross liability exclusion for claims or suits by one insured against another; (3) products/completed operations liability; or (4) contain any other exclusion contrary to the Agreement.
(d) The policy shall give City, the City Council and each member of the City Council, its officers, employees, agents and City designated volunteers additional insured status using ISO endorsement forms CG 20 10 10 01 and 20 37 10 01, or endorsements providing the exact same coverage.
498
BB&K (2023)
46700.00100\40935196.1
-15-
(e) The general liability program may utilize either deductibles or provide coverage excess of a self-insured retention, subject to written approval by the City, and provided that such deductibles shall not apply to the City as an additional insured.
3.15.4 Automobile Liability
(a) At all times during the performance of the work under this Agreement, the Consultant shall maintain Automobile Liability Insurance for bodily injury and property damage including coverage for owned, non-owned and hired vehicles, in a form and with insurance companies acceptable to the City.
(b) Coverage for automobile liability insurance shall be at least as broad as Insurance Services Office Form Number CA 00 01 covering automobile liability (Coverage Symbol 1, any auto).
(c) The policy shall give City, the City Council and each member of the City Council, its officers, employees, agents and City designated volunteers additional insured status.
(d) Subject to written approval by the City, the automobile liability program may utilize deductibles, provided that such deductibles shall not apply to the City as an additional insured, but not a self-insured retention.
3.15.5 Workers’ Compensation/Employer’s Liability
(a) Consultant certifies that he/she is aware of the provisions of Section 3700 of the California Labor Code which requires every employer to be insured against liability for workers’ compensation or to undertake self-insurance in accordance with the provisions of that code, and he/she will comply with such provisions before commencing work under this Agreement.
(b) To the extent Consultant has employees at any time during the term of this Agreement, at all times during the performance of the work under this Agreement, the Consultant shall maintain full compensation insurance for all persons employed directly by him/her to carry out the work contemplated under this Agreement, all in accordance with the “Workers’ Compensation and Insurance Act,” Division IV of the Labor Code of the State of California and any acts amendatory thereof, and Employer’s Liability Coverage in amounts indicated herein. Consultant shall require all subconsultants to obtain and maintain, for the period required by this Agreement, workers’ compensation coverage of the same type and limits as specified in this Section.
3.15.6 Professional Liability (Errors and Omissions)
(a) At all times during the performance of the work under this Agreement the Consultant shall maintain professional liability or Errors and Omissions insurance appropriate to its profession, in a form and with insurance companies acceptable to the City and in an amount indicated herein. This insurance shall be written on a policy form coverage specifically designed to protect against acts, errors or omissions of the Consultant. “Covered Professional Services” as designated in the policy must specifically include work performed under this Agreement. The policy must “pay on behalf of” the insured and must include a provision establishing the insurer's duty to defend.
499
BB&K (2023)
46700.00100\40935196.1
-16-
3.15.7 Minimum Policy Limits Required
(a) The following insurance limits are required for the Agreement:
Coverage Combined Single Limit
Commercial General Liability $2,000,000 per occurrence/ $4,000,000 aggregate for bodily injury, personal
injury, and property damage
Automobile Liability $2,000,000 per occurrence for bodily injury and property damage
Employer’s Liability $1,000,000 per occurrence
Professional Liability $2,000,000 per claim and aggregate (errors and omissions)
(b) Defense costs shall be payable in addition to the limits. (c) Requirements of specific coverage or limits contained in this Section are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance. Any available coverage shall be provided to the parties required to be named as Additional Insured pursuant to this Agreement.
3.15.8 Evidence Required
(a) Prior to execution of the Agreement, the Consultant shall file with the City evidence of insurance from an insurer or insurers certifying to the coverage of all insurance required herein. Such evidence shall include original copies of the ISO CG 00 01 (or insurer’s equivalent) signed by the insurer’s representative and Certificate of Insurance (Acord Form 25-S or equivalent), together with required endorsements. All evidence of insurance shall be signed by a properly authorized officer, agent, or qualified representative of the insurer and shall certify the names of the insured, any additional insureds, where appropriate, the type and amount of the insurance, the location and operations to which the insurance applies, and the expiration date of such insurance.
3.15.9 Policy Provisions Required
(a) Consultant shall provide the City at least thirty (30) days prior written notice of cancellation of any policy required by this Agreement, except that the Consultantshall provide at least ten (10) days prior written notice of cancellation of any such policy due to nonpayment of premium. If any of the required coverage is cancelled or expires during the termof this Agreement, the Consultant shall deliver renewal certificate(s) including the General Liability Additional Insured Endorsement to the City at least ten (10) days prior to the effective date of cancellation or expiration.
(b) The Commercial General Liability Policy and Automobile Policy shall each contain a provision stating that Consultant’s policy is primary insurance and that any insurance, deductible, or self-insurance maintained by the City, its officials, officers, employees, agents, or volunteers shall not contribute with this primary insurance. Policies shall contain or be endorsed to contain such provisions.
500
BB&K (2023)
46700.00100\40935196.1
-17-
(c) The retroactive date (if any) of each policy is to be no later than the effective date of this Agreement. Consultant shall maintain such coverage continuously for a period of at least three years after the completion of the work under this Agreement. Consultant shall purchase a one (1) year extended reporting period A) if the retroactive date is advanced past the effective date of this Agreement; B) if the policy is cancelled or not renewed; or C) if thepolicy is replaced by another claims-made policy with a retroactive date subsequent to the effective date of this Agreement.
(d) All required insurance coverages, except for the professional liability coverage, shall contain or be endorsed to waiver of subrogation in favor of the City, its officials, officers, employees, agents, and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these specifications to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants.
(e) The limits set forth herein shall apply separately to each insured against whom claims are made or suits are brought, except with respect to the limits of liability.
Further the limits set forth herein shall not be construed to relieve the Consultant from liability in excess of such coverage, nor shall it limit the Consultant’s indemnification obligations to the City and shall not preclude the City from taking such other actions available to the City under other provisions of the Agreement or law.
3.15.10 Qualifying Insurers
(a) All policies required shall be issued by acceptable insurance companies, as determined by the City, which satisfy the following minimum requirements: Each such policy shall be from a company or companies with a current A.M. Best's rating of no less than A:VII and admitted to transact in the business of insurance in the State of California, or otherwise allowed to place insurance through surplus line brokers under applicable provisions of the California Insurance Code or any federal law.
3.15.11 Additional Insurance Provisions
(a) The foregoing requirements as to the types and limits of insurance coverage to be maintained by Consultant, and any approval of said insurance by the City, is not intended to and shall not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Consultant pursuant to this Agreement, including but not limited to, the provisions concerning indemnification.
(b) If at any time during the life of the Agreement, any policy of insurance required under this Agreement does not comply with these specifications or is canceled and not replaced, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Consultant or City will withhold amounts sufficient to pay premium from Consultant payments. In the alternative, City may cancel this Agreement.
(c) The City may require the Consultant to provide complete copies of all insurance policies in effect for the duration of the Project. (d) Neither the City nor the City Council, nor any member of the City 501
BB&K (2023)
46700.00100\40935196.1
-18-
Council, nor any of the officials, officers, employees, agents or volunteers shall be personally responsible for any liability arising under or by virtue of this Agreement.
3.15.12 Subconsultant Insurance Requirements
(a) Consultant shall not allow any subcontractors or subconsultants to commence work on any subcontract until they have provided evidence satisfactory to the City that they have secured all insurance required under this Section. Policies of commercial general liability insurance provided by such subcontractors or subconsultants shall be endorsed to name the City as an additional insured using ISO form CG 20 38 04 13 or an endorsement providing the exact same coverage. If requested by Consultant, City may approve different scopes or minimum limits of insurance for particular subcontractors or subconsultants.
3.16 Records.
Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to thisAgreement.
Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of five (5) years from the date of final payment under this Agreement.
3.17 Standardized Manufactured Items.
Consultant shall cooperate and consult with City in the use and selection of manufactured items on the Project, including but not limited to, paint, hardware, plumbing, mechanical and electrical equipment, fixtures, roofing materials and floor coverings. All such manufactured items shall be standardized to City’s criteria to the extent such criteria do not interfere with building design.
3.18 Limitation of Agreement.
This Agreement is limited to and includes only the work included in the Project described herein. Any additional or subsequent construction at the site of the Project, or at any other City site, will be covered by, and be the subject of, a separate Agreement for architectural services between City and the Consultant chosen therefor by City.
3.19 Mediation.
Disputes arising from this Agreement may be submitted to mediation if mutually agreeable to the Parties hereto. The type and process of mediation to be utilized shall be subject to the mutual agreement of the Parties.
3.20 Successors and Assigns.
This Agreement shall be binding upon and shall inure to the benefit of the successors in interest, executors, administrators and assigns of each Party to this Agreement. However, Consultant shall not assign or transfer by operation of law or otherwise any or all of its rights, burdens, duties or obligations without the prior written consent of City. Any attempted assignment without such consent shall be invalid and void.
502
BB&K (2023)
46700.00100\40935196.1
-19-
3.21 Asbestos Certification.
Consultant shall certify to City, in writing and under penalty of perjury, that to the best of its knowledge, information and belief no asbestos-containing material or other material deemed to be hazardous by the state or federal government was specified as a building material in any construction document that the Consultant prepares for the Project. Consultant shall require all consultants who prepare any other documents for the Project to submit the same written certification. Consultant shall also assist the City in ensuring that contractors provide City with certification, in writing and under penalty of perjury, that to the best of their knowledge, information and belief no material furnished, installed or incorporated into the Project contains asbestos or any other material deemed to be hazardous by the state or federal government. These certifications shall be part of the final Project submittal. Consultant shall include statements in its specifications that materials containing asbestos or any other material deemed to be hazardous by the state or federal government are not to be included.
3.22 No Third Party Rights.
This Agreement shall not create any rights in, or inure to the benefits of, any third party except as expressly provided herein.
3.23 Governing Law.
This Agreement shall be construed in accordance with, and governed by, the laws of the State of California. Venue shall be in San Bernardino County.
3.24 Exhibits and Recitals.
All exhibits and recitals contained herein and attached hereto are material parts of this Agreement and are incorporated as if fully set forth.
3.25 Severability.
Should any provision in the Agreement be held by a court of competent jurisdiction to be invalid, void, or unenforceable, the remaining provisions shall continue in full force and effect.
3.26 Non-Waiver.
None of the provisions of this Agreement shall be considered waived by either Party, unless such waiver is specifically specified in writing.
3.27 Safety.
Consultant shall execute and maintain its work so as to avoid injury or damage to any person or property. In carrying out its Services, the Consultant shall at all times be in compliance with all applicable local, state and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of its employees, consultant and subcontractors appropriate to the nature of the work and the conditions under which the work is to be performed.
3.28 Harassment Policy.
Consultant shall provide a copy of the City's Harassment Policy to each of its employees 503
BB&K (2023)
46700.00100\40935196.1
-20-
assigned to perform the tasks under this Agreement. Consultant shall submit to the City's Personnel Manager a statement signed by each of its employees who are assigned to perform the Services under this Agreement certifying receipt of City's Harassment Policy and certifying that they have read the Harassment Policy. A finding by the City that any of Consultant's employees has harassed a City employee shall be grounds for appropriate discipline, up to and including such employee's removal from performance of this Agreement at City's request.
3.29 Delivery of Notices.
All notices permitted or required under this Agreement shall be given to the respective Parties at the following address, or at such other address as the respective Parties may provide in writing for this purpose:
CITY:
City of Ontario
303 East “B” Street
Ontario, CA 91764
Attn: Adrian Escamilla, Design and Construction
CONSULTANT:
M. Arthur Gensler Jr. & Associates, Inc.
500 South Figueroa St.
Los Angeles, CA 90071
Attn: Aaron Birney, Principal
Such notice shall be deemed made when personally delivered or when mailed, forty-eight (48) hours after deposit in the U.S. Mail, first class postage prepaid and addressed to the Party at its applicable address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.
3.30 Time of Essence.
Time is of the essence for each and every provision of this Agreement.
3.31 City’s Right to Employ Other Consultants.
City reserves right to employ other consultants, including designers, in connection with this Project or other project.
3.32 Prohibited Interests.
3.32.1 Solicitation. Consultant maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Consultant, to solicit or secure this Agreement. Further, Consultant warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability.
3.32.2 Conflict of Interest. For the term of this Agreement, no director, official, officer or employee of City, during the term of his or her service with City, shall have any direct 504
BB&K (2023)
46700.00100\40935196.1
-21-
interest in this Agreement, or obtain any present or anticipated material benefit arising therefrom.
3.33 Equal Opportunity Employment.
Consultant represents that it is an equal opportunity employer and that it shall not discriminate against any employee or applicant for employment because of race, religion, color, national origin, ancestry, sex, age or any other classification protected by federal or state law.
Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination. Consultant shall also comply with all relevant provisions of City’s minority business enterprise program, affirmative action plan or other related programs or guidelines currently in effect or hereinafter enacted.
3.34 Labor Certification.
By its signature hereunder, Consultant certifies that it is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker’s Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services.
3.35 Subcontracting.
As specified in this Agreement, Consultant shall not subcontract any portion of the Services required by this Agreement, except as expressly stated herein, without prior written approval of City. Subcontracts, if any, shall contain a provision making them subject to each and every provision of this Agreement.
3.36 Supplemental Conditions.
Any supplemental conditions shall be attached as an exhibit to this Agreement, and that exhibit shall be incorporated herein by reference.
3.37 Entire Agreement.
This Agreement, with its exhibits, contains the entire agreement of the Parties hereto, and supersedes any and all other prior or contemporaneous negotiations, understandings and oral or written agreements between the Parties hereto. Each Party acknowledges that no representations, inducements, promises or agreements have been made by any person which are not incorporated herein, and that any other agreements shall be void. Furthermore, any modification of this Agreement shall only be effective if in writing signed by all Parties hereto.
SIGNATURES ON FOLLOWING PAGE
505
BB&K (2023)
46700.00100\40935196.1
-22-
SIGNATURE PAGE FOR DESIGN SERVICES AGREEMENT
BETWEEN THE CITY OF ONTARIO
AND M. ARTHUR GENSLER JR. &
ASSOCIATES, INC.
IN WITNESS WHEREOF, the Parties have executed this Agreement as of the date first written above.
CITY OF ONTARIO
M. ARTHUR GENSLER JR.&ASSOCIATES,
INC
By:
Its:
Printed Name:
By:
Its:
Printed Name:
[If Corporation, TWO SIGNATURES,
President OR Vice President AND Secretary
OR Treasurer REQUIRED]
Approved By:
Scott Ochoa
City Manager
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:
City Clerk
506
BB&K (2023)
46700.00100\40935196.1
Exhibit A-1
EXHIBIT “A”
SCOPE OF SERVICES
1. GENERAL REQUIREMENTS.
1.1 Basic Services. Consultant agrees to perform all the necessary professional architectural, engineering (e.g. mechanical, electrical, plumbing, structural, site engineering, and any other necessary engineering services mutually agreeable to the Parties) and construction administration services for the Project in a timely and professional manner, consistent with the standards of the profession, including those provided for herein.
1.2 Exclusions from Basic Services. The following services shall be excluded from the basic services listed above: Exclusions will be determined on a project-by-project basis.
1.3 Additional Services. Consultant shall perform the following Additional Services for the Project: Additional Services will be determined on a project by project.
1.4 Communication with City. Consultant shall participate in consultations and conferences with authorized representatives of City and/or other local, regional, or state agencies concerned with the Project, which may be necessary for the completion of the Project or the development of the drawings, specifications and documents in accordance with the applicable standards and requirements of law and the City. Such consultations and conferences shall continue throughout the planning and construction of the Project and the contractor’s warranty period. Consultant shall take direction only from the City’s Representative, or any other representative specifically designated by the City for this Project, including any construction manager hired by the City.
1.5 Coordination and Cooperation with Construction Manager. The City may hire a construction manager to administer and coordinate all or any part of the Project on its behalf. If the City does so, it shall provide a copy of its agreement with the construction manager so that the Consultant will be fully aware of the duties and responsibilities of the construction manager.
The Consultant shall cooperate with the construction manager and respond to any requests or directives authorized by the City to be made or given by the construction manager. The Consultant shall request clarification from the City in writing if the Consultant should have any questions regarding the authority of the construction manager.
2. INITIAL PLANNING PHASE.
During the initial planning phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
2.1 Project Feasibility. Provide advice and assistance to City in determining the feasibility of the Project, analysis of the type and quality of materials and construction to be selected, the site location, and other initial planning matters.
2.2 Meeting Budget and Project Goals. Consultant shall notify City in writing of potential complications, cost overruns, unusual conditions, and general needs that potentially impact the Project budget and time line, including the City’s Preliminary Construction Budget.
Consultant shall use its best judgment in determining the balance between the size, type and 507
BB&K (2023)
46700.00100\40935196.1
Exhibit A-2
quality of construction to achieve a satisfactory solution within the Project’s budget and construction allowance. It shall be the duty of the Consultant to design the Project within budget.
As discussed herein, including in Section 7.3, if the lowest responsive and responsible bid for the Project exceeds the budget by the stated amount, Consultant may be required to make the necessary changes in the drawing and specifications, at its sole cost and expense, to bring the bids within the required budget.
2.3 Permits, Approvals and Authorizations. As indicated in Section 3.5.4 of the Agreement, Consultant shall assist City in securing easements, encroachment permits, rights of way, dedications, infrastructures and road improvements, as well as coordinating with utilities and adjacent property owners.
3. SCHEMATIC PLAN PHASE.
During the schematic plan phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
3.1 Funding Documents. Consultant shall provide a site plan and all other Projectrelated information necessary and required for an application by City to any federal, state, regional, or local agencies for funds to finance the construction Project.
3.2 Schematic Plans. In cooperation with City, Consultant shall prepare preliminary plans and studies, schematic drawings, site utilization plans, and phasing plans showing the scale and relationship of the components of the Project, the plot plan development at the site, and the proposed architectural concept of the buildings (“Schematic Plans”). Consultant shall incorporate the functional requirements of City into the Schematic Plans. The Schematic Plans shall meet all laws, rules and regulations of the State of California. The Schematic Plans shall show all rooms incorporated in each building of the Project in single-line drawings, and shall include all revisions required by City or by any federal, state, regional or local agency having jurisdiction over the Project. All architectural drawings for the Project shall be in a form suitable for reproduction.
3.3 Preliminary Project Budget. Consultant shall use the City’s Preliminary Construction Budget and its own expertise and experience with the Project to establish a preliminary project budget or allowance in a format required by City (“Consultant’s Preliminary Project Budget”). The purpose of the Consultant’s Preliminary Project Budget is to show the probable Project cost in relation to City’s Preliminary Construction Budget and the construction standards of any applicable funding agency. If Consultant perceives site considerations which render the Project expensive or cost prohibitive, Consultant shall disclose such conditions in writing to City immediately. As discussed herein, including in Section 7.3, if the lowest responsive and responsible bid for the Project exceeds the budget by more than the stated amount, Consultant may be required to make the necessary changes in the drawings and specifications, at its sole cost and expense, to bring the bids within the required budget Consultant shall provide a preliminary written time schedule for the performance of all construction work on the Project.
3.4 Copies of Schematic Plans and Other Documents. Consultant, at its own expense, shall provide a complete set of the Schematic Plans described herein for City’s review and approval. Additionally, at City’s expense, Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any additional copies required by City shall be provided at actual cost to City. 508
BB&K (2023)
46700.00100\40935196.1
Exhibit A-3
4. DESIGN DEVELOPMENT PHASE.
During the design development phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
4.1 Design Development Documents. Once City provides Consultant with specific written approval of the Schematic Plans described herein, Consultant shall prepare design development documents consisting of: (1) site and floor plans; (2) elevations; and (3) any other drawings and documents sufficient to fix and describe the types and makeup of materials, as well as the size and character of the Project’s structural, mechanical and electrical systems, and to outline the Project specifications (“Design Development Documents”). The Design Development Documents shall be prepared in sufficient form to present to the City Council for approval.
4.2 Copies of Design Development and Other Documents. Consultant, at its own expense, shall provide a complete set of the Design Development Documents described herein for City’s review and approval. Additionally, at City’s expense, Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any additional copies required by City shall be provided at actual cost to City.
4.3 Updated Project Budget. Consultant shall use its Preliminary Project Budget and expertise and experience with the Project to establish an updated estimate of probable construction costs, containing detail consistent with the Design Development Documents as set forth herein and containing a breakdown based on types of materials and specifications identified herein (“Consultant’s Updated Project Budget”).
4.4 Timetable. Consultant shall provide a written timetable for full and adequate completion of the Project to City.
4.5 Application for Approvals. Consultant shall assist City in applying for and obtaining required approvals from all federal, state, regional or local agencies concerned with the Project. Consultant shall furnish and process all architectural and engineering information required to prepare and process applications to applicable utilities in order to secure priorities and materials, to aid in the construction of the Project and to obtain final Project approval and acceptance by any of the above agencies as may be required.
4.6 Color and Other Aesthetic Issues. Consultant shall provide, for City’s review and approval, a preliminary schedule of all color materials and selections of textures, finishes andother matters involving an aesthetic decision about the Project.
5. FINAL WORKING DRAWINGS AND SPECIFICATIONS.
During the final working drawings and specifications phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
5.1 Final Working Drawings and Specifications. Once City provides Consultant with specific written approval of the Design Development Documents described herein, Consultant shall prepare such complete working drawings and specifications as are necessary for developing complete bids and for properly executing the Project work in an efficient and thorough manner (“Final Working Drawings and Specifications”). Such Final Working Drawings and Specifications shall be developed from the Schematic Plans and Design Development Documents approved by City. The Final Working Drawings and Specifications shall set forth in 509
BB&K (2023)
46700.00100\40935196.1
Exhibit A-4
detail all of the following: (1) the Project construction work to be done; (2) the materials, workmanship, finishes, and equipment required for the architectural, structural, mechanical, and electrical systems; and (3) the utility service connection equipment and site work. As indicated in Section 3.9.2 of the Agreement, City may be requested to supply Consultant with the necessary information to determine the proper location of all improvements on and off site, including record drawings (“as-built drawings”) in City’s possession. Consultant will make a good-faith effort to verify the accuracy of such information by means of a thorough interior and exterior visual survey of site conditions. City shall also make a good-faith effort to verify the accuracy of the as-built drawings and provide any supplemental information to Consultant which may not be shown on the as-built drawings.
5.2 Form. The Final Working Drawings and Specifications must be in such form as will enable Consultant and City to secure the required permits and approvals from all federal, state, regional or local agencies concerned with the Project. In addition, the Final Working Drawings and Specifications must be in such form as will enable City to obtain, by competitive bidding, a responsible and responsive bid within the applicable budgetary limitations and cost standards.
The Final Working Drawings and Specifications shall be clear and legible so that uniform copies may be on standard architectural size paper, properly indexed and numbered, andshall be capable of being clearly copied and assembled in a professional manner by Consultant.
5.3 Approval and Revisions. City shall review, study, and check the Final Working Drawings and Specifications presented to it by Consultant, and request any necessary revisions or obtain any necessary approvals by the City Council, subject to the approval of all federal, state, regional or local agencies concerned with the Project. Consultant shall make all City-requested changes, additions, deletions, and corrections in the Final Working Drawings and Specifications at no additional cost, so long as they are not in conflict with the requirements of public agencies having jurisdiction or prior approval, or inconsistent with earlier City direction or Consultant’s professional judgment. Consultant shall bring any such conflicts and/or inconsistencies to the attention of City. The Parties agree that Consultant, and not the City, possesses the requisite expertise to determine the constructability of the Final Working Drawings and Specifications.
However, the City reserves the right to conduct one or more constructability review processes with the Final Working Drawings and Specifications, and to hire an independent architect or other consultant to perform such reviews. Any such independent constructability review shall be at City’s expense. Consultant shall make all City-requested changes, additions, deletions, and corrections in the Final Working Drawings and Specifications which may result from any constructability review, at no additional cost to the City, so long as they are not in conflict with the requirements of public agencies having jurisdiction or prior approval, or inconsistent with earlier City direction or Consultant’s professional judgment. If such changes, additions, deletions or corrections are inconsistent with prior City direction, Consultant shall make such alterations and be compensated therefore pursuant to the Additional Services provision of this Agreement.
5.4 Costs of Construction. It is understood by Consultant that should the Final Working Drawings and Specifications be ordered by City, City shall specify the sum of money set aside to cover the total cost of construction of the work, exclusive of Consultant’s fees. Should it become evident that the total construction cost will exceed the specified sum, Consultant shall at once present a statement in writing to the City’s Representative setting forth this fact and giving a full statement of the cost estimates on which the conclusion is based.
5.5 Copies of Final Working Drawings and Specifications and Other Documents.
Consultant, at its own expense, shall provide a complete set of the Final Working Drawings and Specifications described herein for City’s review and approval. Additionally, at City’s expense, 510
BB&K (2023)
46700.00100\40935196.1
Exhibit A-5
Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any additional copies required by City shall be provided at actual cost to City.
6. CONSTRUCTION CONTRACT DOCUMENTS.
During the construction contract documents phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
6.1 Bid and Contract Documents. If so required by City, Consultant shall assist City in the completion of all bid and construction documents, including but not limited to, the Notice Inviting Bids, Instructions to Bidders, Contract Bid Forms (including Alternate Bids as requested by City), `Contract, General Conditions, Supplementary General Conditions, Special Conditions, DVBE and other applicable affirmative action documents, Performance Bond, Payment Bond, Escrow Agreement for Security Deposits, and any other certifications and documents required by federal, state and local laws, rules and regulations which may be reasonably required in order to obtain bids responsive to the specifications and drawings. All such documents shall be subject to the approval of City and City’s legal counsel.
6.2 Final Estimate. At the time of delivery of these bid and construction documents, which shall include the Final Working Drawings and Specifications (collectively referred to herein as the “Construction Documents”), Consultant shall provide City with its final estimate of probable construction cost (“Consultant’s Final Estimate”). As discussed herein, including in Section 7.3, it shall be the Consultant’s duty to design the Project within budget.
7. BID PHASE.
During the bid phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
7.1 Reproducible Construction Documents. Once City provides Consultant with specific written approval of the Construction Documents and Consultant’s Final Estimate, Consultant shall provide to City one set of reproducible Construction Documents.
7.2 Distribution of Contract Documents and Review of Bids. Consultant shall assist City in distributing the Construction Documents to bidders and conducting the opening and review of bids for the Project.
7.3 Over Budget. If the apparent lowest responsive and responsible bid on the Project exceeds the Consultant’s Final Estimate by more than five percent (5%), City may request Consultant to amend, at Consultant’s sole cost and expense, the Final Drawings and Specifications in order to rebid the Project and receive a lowest responsive and responsible bid equal to or less than the Consultant’s Final Estimate. All revisions necessary to bring the lowest responsible and responsive bid within the Consultant’s Final Estimate, including any omissions, deferrals or alternates, shall be made in consultation with, and subject to the approval of, the City.
8. CONSTRUCTION PHASE.
During the construction phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
511
BB&K (2023)
46700.00100\40935196.1
Exhibit A-6
8.1 Observation. The Project Consultant shall observe work executed from the Final Working Drawings and Specifications in person, provided that City may, in its discretion, consent to such observation by another competent representative of Consultant.
8.2 General Administration. Consultant shall provide general administration of the Construction Documents and the work performed by the contractors.
8.3 Pre-Construction Meeting. Consultant shall conduct one or more preconstruction meetings, as the City determines is needed for the Project, with all interested Parties.
8.4 Site Visits of Contractor’s Work. Consultant shall conduct site visits to observe each contractors’ work for general conformance with the Construction Documents and with any approved construction schedules or milestones. Such site visits shall be conducted as often as are necessary and appropriate to the stage of construction, according to the City’s sole discretion, but in no event less than weekly.
8.5 Site Visits of Inspector’s Work. Consultant shall conduct site visits to communicate and observe the activities of the City inspectors. Such site visits shall be conducted as often as is mutually acceptable to Consultant and City. Consultant shall direct the City inspectors and the Project contractors to coordinate the preparation of record drawings indicating dimensions and location of all “as-built” conditions, including but not limited to, underground utility lines.
8.6 Coordination of Subconsultants. Consultant shall cause all architects, engineers and other consultants, as may be hired by Consultant or City, to observe the work completed under their disciplines as required, and approve and review all test results for general conformance with the Construction Documents.
8.7 Reports. Consultant shall make regular reports as may be required by applicable federal, state or local laws, rules or regulations, as well as the federal, state, regional or local agencies concerned with the Project.
8.8 Construction Meetings; Minutes. Consultant shall attend all construction meetings and provide written reports/minutes to the City after each construction meeting in order to keep City informed of the progress of the work. Such meetings shall occur at a frequency necessary for the progress of the Project work, according to the City’s sole discretion, but no less than weekly.
8.9 Written Reports. Consultant shall make written reports to City as necessary to inform City of problems arising during construction, changes contemplated as a result of each such problems, and progress of the Project work.
8.10 Written Records. Consultant shall keep accurate written records of the progress and quality of the Project work and the time schedules, and shall advise the contractors and City of any deviations from the time schedule which could delay timely completion of the Project.
8.11 Material and Test Reports. Consultant shall check and process, in a timely manner, all required material and test reports for the Project work. In addition, Consultant shall provide notice of any deficiencies in material or work reflected in such reports, as well as its recommendation for correction of such deficiencies, to the contractors and City. 512
BB&K (2023)
46700.00100\40935196.1
Exhibit A-7
8.12 Review and Response to Submissions. Consultant shall review and respond, in a timely manner, to all schedules, submittals, shop drawings, samples, information requests, change requests, and other submissions of the contractor and subcontractors for compliance with, or alterations and additions to, the Construction Documents. Consultant’s review and response shall be done in such a manner so as to ensure the timely and uninterrupted progress of the Project work.
8.13 Rejection of Work. Consultant shall promptly reject, as discussed with City, work or materials which do not conform to the Construction Documents. Consultant shall immediately notify the City and contractor(s) of such rejections. Consultant shall also have the authority to recommend to the City that additional inspection or testing of the work be performed, whether or not such work is fabricated, installed or completed.
8.14 Substitutions. Consultant shall consult with City, in a timely manner, with regard to substitution of materials, equipment and laboratory reports thereof, prior to the City’s final written approval of such substitutions. Consultant’s consultation shall be done in such a manner so as to ensure the timely and uninterrupted progress of the Project work.
8.15 Revised Documents and Drawings. Consultant shall prepare, at no additional expense to City, all documents and/or drawings made necessary by errors and omissions in the originally approved Construction Documents.
8.16 Change Requests and Material Changes. Consultant shall evaluate and advise City, in a timely manner and in writing, of any change requests and material change(s) which may be requested or necessary in the Project plans and specifications. Consultant shall provide the City with its opinion as to whether such change requests should be approved, denied or revised.
If the City has not hired a construction manager or other person to do so, the Consultant shall prepare and execute all change orders and submit them to the City for authorization. If the City has designated a construction manager or other person to prepare all change orders, the Consultant shall review all change orders prepared by such person, execute them and deliver them to the City for authorization if they meet with the Consultant’s approval, or submit them to the City with recommendations for revision or denial if necessary. Consultant shall not order contractors to make any changes affecting the contract price without approval by City of such a written change order, pursuant to the terms of the Construction Documents. Consultant may order, on its own responsibility and pending City Council approval, changes necessary to meet construction emergencies, if written approval of City’s Representative is first secured.
8.17 Applications for Payment. Consultant shall examine, verify and approve contractor’s applications for payment, and shall issue certificates for payment in amounts approved by the City’s inspector.
8.18 Final Color and Product Selection. Consultant shall coordinate final color and product selection with City’s original design concept.
8.19 Substantial Completion. Consultant shall determine the date of substantial completion, in consultation with the City.
8.20 Punch List. After determining that the Project is substantially complete, Consultant shall participate in the inspection of the Project and shall review all remaining deficiencies and minor items needed to be corrected or completed on the Project, including those identified on the punch list prepared by the contractor (“Punch List Items”). Consultant shall notify 513
BB&K (2023)
46700.00100\40935196.1
Exhibit A-8
contractor in writing that all Punch List Items must be corrected prior to final acceptance of the Project and final payment. Consultant shall also notify City of all Punch List Items.
8.21 Warranties. Consultant shall review materials assembled by the contractor and subcontractors with regard to all written warranties, guarantees, owners’ manuals, instruction books, diagrams, record “as built” drawings, and any other materials required from the contractors and subcontractors pursuant to the Construction Documents. Consultant shall coordinate and provide these materials to the City.
8.22 Certificate of Completion. Consultant shall participate in any further inspections of the Project necessary to issue Consultant’s Certificate of Completion and final certificate for payment.
8.23 Documents for Project Close-Out. Consultant shall cause all other architects, engineers and other consultants, as may be hired by Consultant, to file any and all required documentation with the City or other governmental authorities necessary to close out the Project.
Consultant shall assist the City in obtaining such documentation from all other architects, engineers, or other consultants.
9. AS-BUILT DRAWINGS.
During the as-built drawings phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
9.1 As-Built Drawings and Specifications. Not later than thirty (30) days after substantial completion of the Project, before receipt of final payment, Consultant shall review and forward the Final Working Drawings and Specifications, indicating on them all changes made by change orders or otherwise pursuant to the Construction Documents, as well as all information called for on the specifications, thus producing an “as-built” set of Final Working Drawings and Specifications (“As-Built Drawings and Specifications”). The As-Built Drawings and Specifications shall show, among other things, the location of all concealed pipe, buried conduit runs and other similar elements within the completed Project. Consultant shall personally review and certify that the As-Built Drawings and Specifications are a correct representation of the information supplied to Consultant by any inspectors and the contractor, and shall obtain certifications from any inspectors and the contractor that the drawings are correct.
9.2 Approval. Once City provides Consultant with specific written approval of the AsBuilt Drawings and Specifications, Consultant shall forward to City the complete set of original AsBuilt Drawings and Specifications or a complete set of reproducible duplicate As-Built Drawings and Specifications. The tracing shall be of such quality that clear and legible prints maybe made without appreciable and objectionable loss of detail.
9.3 Documents for Final Payment. Prior to the receipt of Consultant’s final payment, Consultant shall forward to City all of the following: (1) one clear and legible set of reproductions of the computations; (2) the original copy of the specifications; (3) the As-Built Drawings and Specifications as required herein; and (4) Consultant’s Certificate of Completion.
10. WARRANTY PERIOD.
During the warranty period phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
514
BB&K (2023)
46700.00100\40935196.1
Exhibit A-9
10.1 Advice. Consultant shall provide advice to City on apparent deficiencies in the Project during any applicable warranty periods for the Project. 515
BB&K (2023)
46700.00100\40935196.1
Exhibit B-1
EXHIBIT “B”
FEE AND PHASING/FUNDING SCHEDULES
1. FEE SCHEDULE.
Consultant will invoice City on a monthly cycle based on the following fee schedule.
Consultant will include with each invoice a detailed progress report that indicates the amount of budget spent on each phase and the total amount spent against the Total Compensation.
Consultant will inform City regarding any out-of-scope work being performed by Consultant for which Consultant intends to seek compensation from City.
2. PHASING/FUNDING SCHEDULE.
Progress payments towards Total Compensation shall never exceed the following percentages of Total Compensation as of the phase indicated:
516
517
BB&K (2023)
46700.00100\40935196.1
-1-
CITY OF ONTARIO
DESIGN SERVICES AGREEMENT
1. PARTIES AND DATE.
This Agreement is made and entered into as of , by and between the City of Ontario, a municipal corporation organized and operating under the laws of the State of California with its principal place of business at 303 East “B” Street, Ontario, California 91764- 4196, County of San Bernardino, State of California (“City”), and Miller Architectural Corporation, a corporation with its principal place of business at 1177 Idaho Street, Suite 200 Redlands, CA 92374 (hereinafter referred to as “Consultant”). City and Consultant are sometimes individually referredto herein as “Party” and collectively as “Parties.”
2. RECITALS.
2.1 City. City is a municipal corporation organized under the laws of the State of California, with power to contract for services necessary to achieve its purpose.
2.2 Consultant. Consultant desires to perform and assume responsibility for the provision of certain professional architectural design services requiredby the City on the terms and conditions set forth in this Agreement. Consultant warrants that it isfully licensed, qualified, and willing to perform the services required by this Agreement; provided, however, that if Consultant is a corporation or other organization, the Project Consultant designated pursuant to Section 3.2, and not the Consultant itself, shall be fully licensed to practiceas an architect in the State of California.
2.3 Project. City desires to engage Consultant to render such services for the On-Call Retail Architect Design Services ("Project") as set forth in this Agreement.
3. TERMS
3.1 Employment of Consultant.
3.1.1 Scope of Services. Consultant promises and agrees to furnish to City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the professional architectural and related services necessary for the full and adequate completion of the Project consistent with the provisions of this Agreement 518
BB&K (2023)
46700.00100\40935196.1
-2-
(hereinafter referred to as “Services”). The Services are more particularly described throughout this Agreement, including Exhibit “A” attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordancewith, this Agreement, any exhibits attached hereto and incorporated herein by reference, and allapplicable local, state and federal laws, rules and regulations. All Services performed by Consultant shall be subject to the sole and discretionary approval of the City, which approval shallnot be unreasonably withheld.
3.1.2 Term. The term of this Agreement shall be from July 16, 2024, to July 16, 2027, The City shall have the unilateral option, at its sole discretion, to renew this Agreement automatically for no more than two additional one-year terms unless earlier terminated as provided herein. Consultant shall complete the Services within the term of agreement and shall meet any other established scheduled and deadlines.
3.2 Project Consultant; Key Personnel.
3.2.1 Retail Architect. Consultant shall name a specific individual to act as Project Consultant, subject to the approval of City. Consultanthereby designates Gary Miller (License No. #C14635) to act as the Retail Architect for the Project. The Architect shall: (1) maintain oversight of the Services; (2) have full authority to represent and act on behalf of the Consultant for all purposes under thisAgreement; (3) supervise and direct the Services using his or her best skill and attention; (4) be responsible for the means, methods, techniques, sequences and procedures used for theServices; (5) adequately coordinate all portions of the Services; and (6) act as principal contact with y and all contractors, consultants, engineers and inspectors on the Project.
Any change in the Retail Architect shall be subject to the City’s prior written approval, which approval shall not be unreasonably withheld. The new Retail Architect shall be of at least equal competence as the prior Retail Architect. In the event that City and Consultant cannotagree as to the substitution of a new Retail Architect. City shall be entitled to terminate this Agreement for cause.
3.2.2 Key Personnel. In addition to the Retail Architect, Consultant has represented to the City that certain additional key personnel, engineers and consultants will perform the Services under this Agreement. Should one or more of such personnel, engineers or consultants become unavailable, Consultant may substitute others of atleast equal competence upon written approval of the City. In the event that City and Consultant cannot agree as to the substitution of key personnel, engineers or consultants, City shall be entitled to terminate this Agreement for cause. The key additional personnel, engineers and consultants for performance of this Agreement are as follows: Gary Miller (License No. #C14635)
3.3 Hiring of Consultants and Personnel.
3.3.1 Right to Hire or Employ. Consultant shall have the option, unless City objects in writing after notice, to employ at its expense architects, engineers, experts or other consultants qualified and licensed to render services in connection with the planning and/or administration of the Project, and to delegate to them such duties as Consultant may delegate without relieving Consultant from administrative or other responsibility under this Agreement.
Consultant shall be responsible for the coordination and cooperation of Consultant’s architects, engineers, experts or other consultants. All consultants, including changes in consultants, shall be subject to approval by City in its sole and reasonable discretion. Consultant shall notify City of the identity of all consultants at least fourteen (14) days prior to their commencement of work 519
BB&K (2023)
46700.00100\40935196.1
-3-
to allow City to review their qualifications and approve to their participation on the Project in its sole and reasonable discretion.
3.3.2 Qualification and License. All architects, engineers, experts and other consultants retained by Consultant in performance of this Agreement shall be qualified to perform the Services assigned to them, and shall be licensed to practice in their respective professions, where required by law.
3.3.3 Standards and Insurance. All architects, engineers, experts and other consultants hired by Consultant shall be required to meet all of the same standards and insurance requirements set forth in this Agreement, unless other standards or requirements are approved by the City in writing. Unless changes are approved in writing by the City, Consultant’s agreements with its consultants shall contain a provision making them subject to all provisions stipulated in this Agreement.
3.3.4 Assignments or Staff Changes. Consultant shall promptly obtain written City approval of any assignment, reassignment or replacement of such architects, engineers, experts and consultants, or of other staff changes of key personnel working on the Project. As provided in the Agreement, any changes in Consultant’s consultants and key personnel shall be subject to approval by City.
3.3.5 Draftsman and Clerical Support. Draftsmen and clerical personnel shall be retained by Consultant at Consultant’s sole expense.
3.4 Standard of Care.
3.4.1 Standard of Care. Consultant shall perform all Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals qualified to perform the Services in the same discipline in the State of California, and shall be responsible to City for damages sustained by the City and delays to the Project as specified in the indemnification provision of this Agreement. Without limiting the foregoing, Consultant shall be fully responsible to the City for any increased costs incurred by the City as a result of any such delays in the design or construction of the Project. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services. Consultant warrants and represents that all of its employees, architects, engineers, experts and other consultants shall have sufficient skill and experience to perform the Services assigned to them. Finally, Consultant represents that it, its employees, architects, engineers, experts and other consultants have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services assigned to or rendered by them and that such licenses and approvals shall be maintained throughout the term of this Agreement. As provided for in the indemnification provisions of this Agreement, Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant’s failure to comply with the standard of care provided for herein.
3.4.2 Performance of Employees. Any employee or consultant who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee or consultant who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed from the Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.
520
BB&K (2023)
46700.00100\40935196.1
-4-
3.5 Laws and Regulations.
3.5.1 Knowledge and Compliance. Consultant shall keep itself fully informed of and in compliance with all applicable local, state and federal laws, rules and regulations in any manner affecting the performance of the Services or the Project, and shall give all notices required of the Consultant by law. Consultant shall be liable, pursuant to the standard of care and indemnification provisions of this Agreement, for all violations of such laws and regulations in connection with its Services. Consultant shall defend, indemnify and hold City, its officials, officers, employees and agents free and harmless, pursuant to the indemnification provisions of this Agreement, from any claim or liability arising out of any failure or alleged failure to comply with such laws, rules or regulations.
3.5.2 Drawings and Specifications. Consultant shall cause all drawings and specifications to conform to any applicable requirements of federal, state and local laws, rules and regulations, including the Uniform Building Code, in effect as of the time the drawings and specifications are prepared or revised during the latest phase of the Services described in Exhibit “A” attached hereto. Any significant revisions made necessary by changes in such laws, rules and regulations after this time may be compensated as Additional Services which were not knownor reasonably should not have been known by Consultant. Consultant shall cause the necessary copies of such drawings and specifications to be filed with any governmental bodies with approval jurisdiction over the Project, in accordance with the Services described in Exhibit “A” attached hereto. For the preparation of all such drawings and specifications, the Consultant shall use Computer Aided Design Drafting (“CADD”) (e.g., AutoCAD) or other technology acceptable to the Consultant and City.
3.5.3 Americans with Disabilities Act. Consultant will use its best professional efforts to interpret all applicable federal, state and local laws, rules and regulations with respect to access, including those of the Americans with Disabilities Act (“ADA”). Consultant shall inform City of the existence of inconsistencies of which it is aware or reasonably should be aware between federal and state accessibility laws, rules and regulations, as well as any other issues which are subject to conflicting interpretations of the law, and shall provide the City with its interpretation of such inconsistencies and conflicting interpretations. Unless Consultant brings such inconsistencies and conflicting interpretations to the attention of the City and requests City’s direction on how to proceed, the Consultant’s interpretation of such inconsistencies and conflicting interpretations shall be the sole responsibility and liability of Consultant, and the Consultant shall correct all plans, specifications and other documents prepared for the Project at no additional cost if its interpretations are shown to be incorrect. In the event that the Consultant request’s City’s direction on how to proceed with respect to any inconsistent and/or conflicting interpretation, the Consultant shall be responsible to the City only pursuant to the indemnification provisions of this Agreement.
3.5.4 Permits, Approvals and Authorizations. Consultant shall provide City with a list of all permits, approvals or other authorizations required for the Project from all federal, stateor local governmental bodies with approval jurisdiction over the Project. Consultant shall then assist the City in obtaining all such permits, approvals and other authorizations. The costs of such permits, approvals and other authorizations shall be paid by the City.
3.5.5 Water Quality Management and Compliance. Consultant shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance 521
BB&K (2023)
46700.00100\40935196.1
-5-
of the Services including, without limitation, all applicable provisions of the City’s ordinances regulating water quality and storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251 et seq.); the California Porter-Cologne Water Quality Control Act (Cal Water Code §§ 13000- 14950); and any and all regulations, policies, or permits issued pursuant to any such authority.
Consultant shall additionally comply with the lawful requirements of the City, and any other municipality, drainage district, or other local agency with jurisdiction over the location where the Services are to be conducted, regulating water quality and storm water discharges. Failure to comply with laws, regulations, and ordinances listed in this Section is a violation of federal and state law.
3.6 Independent Contractor.
3.6.1 Control and Payment of Subordinates. City retains Consultant on an independent contractor basis and Consultant is not an employee of City. Consultant is not an employee for state tax, federal tax or any other purpose, and is not entitled to the rights or benefits afforded to City’s employees. Any additional personnel performing the Services under this Agreement on behalf of Consultant shall also not be employees of City, and shall at all times be under Consultant’s exclusive direction and control. Consultant shall pay all wages, salaries, and other amounts due such personnel in connection with their performance of Services under this Agreement and as required by law. Consultant shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers’ compensation insurance.
3.7 Schedule of Services.
3.7.1 Consultant Services. Consultant shall fully and adequately complete the Services described in this Agreement and in Exhibit “A” attached hereto and incorporated herein by reference.
3.7.2 Timely Performance Standard. Consultant shall perform all Services hereunder as expeditiously as is consistent with professional skill and care, as well as the orderly progress of the Project work so as not to be the cause, in whole or in part, of delays in the completion of the Project or in the achievement of any Project milestones, as provided herein.
Specifically, Consultant shall perform its Services so as to allow for the full and adequate completion of the Project within the time required by the City and within any completion schedules adopted for the Project. Consultant agrees to coordinate with City’s staff, contractors and consultants in the performance of the Services, and shall be available to City’s staff, contractors and consultants at all reasonable times.
3.7.3 Performance Schedule. Consultant shall prepare an estimated time schedule for the performance of Consultant’s Services, to be adjusted as the Project proceeds.
Such schedule shall be subject to the City’s review and approval, which approval shall not be unreasonably withheld, and shall include allowances for periods of time required for City’s review and approval of submissions, and for approvals of authorities having jurisdiction over Project approval and funding. If City and Consultant cannot mutually agree on a performance schedule, City shall have the authority to immediately terminate this Agreement. The schedule shall not be exceeded by Consultant without the prior written approval of City. If the Consultant’s Services are not completed within the time provided by the agreed upon performance schedule, or any milestones established therein, it is understood, acknowledged and agreed that the City will suffer damage for which the Consultant will be responsible.
522
BB&K (2023)
46700.00100\40935196.1
-6-
3.7.4 Excusable Delays. Any delays in Consultant’s work caused by the following may be added to the time for completion of any obligations of Consultant: (1) the actionsof City or its employees; (2) the actions of those in direct contractual relationship with City; (3) theactions of any governmental agency having jurisdiction over the Project; (4) the actions of any parties not within the reasonable control of the Consultant; and (5) any Force Majeure Event (asdefined herein) or other unforeseen occurrence not due to any fault or negligence on the part of Consultant. Neither the City nor the Consultant shall be liable for damages, liquidated or otherwise, to the other on account of such delays.
3.7.5 Force Majeure Events. Neither City nor Consultant shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the non-performing Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Consultant and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the Services and Agreement. Should a Force Majeure Event occur, the nonperforming Party shall, within fifteen (15) calendar days of the beginning of an Force Majeure Event, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events shall not entitle Consultant to any additional compensation. Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement.
3.7.6 Request for Excusable Delay Credit. The Consultant shall, within fifteen (15) calendar days of the beginning of any excusable delay, notify the City in writing of the causes of delay (unless City grants in writing a further period of time to file such notice prior to the date of final payment under the Agreement). City will then ascertain the facts and the extent of the delay, and grant an extension of time for completing the Services when, in its sole judgment, the findings of fact justify such an extension. The City’s findings of fact thereon shall be final and conclusive on the Parties. Extensions of time shall apply only to that portion of the Services affected by the delay and shall not apply to other portions of the Services not so affected. The sole remedy of Consultant for extensions of time shall be an extension of the performance time at no cost to the City. If Additional Services are required as a result of an excusable delay, the Parties shall mutually agree thereto pursuant to the Additional Services provision of this Agreement. Should Consultant make an application for an extension of time, Consultant shall submit evidence that the insurance policies required by this Agreement remain in effect during the requested additional period of time.
3.8 Additional Services.
3.8.1 Request for Services. At City’s request, Consultant may be asked to perform services not otherwise included in this Agreement, not included within the basic services 523
BB&K (2023)
46700.00100\40935196.1
-7-
listed in Exhibit “A” attached hereto, and/or not customarily furnished in accordance with generally accepted architectural practice.
3.8.2 Definition. As used herein, “Additional Services” mean: (1) any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary for the Consultant to perform at the execution of this Agreement; or (2) any work listed as Additional Services in Exhibit “A” attached hereto. Consultant shall not perform, nor be compensated for, Additional Services without prior written authorization from City and without an agreement between the City and Consultant as to the compensation to be paid for such services. City shall pay Consultant for any approved Additional Services, pursuant to the compensation provisions herein, so long as such services are not made necessary through the fault of Consultant pursuant to the indemnification provision of this Agreement.
3.8.3 Examples of Additional Services. Such Additional Services shall notinclude any redesign or revisions to drawings, specifications or other documents when such revisions are necessary in order to bring such documents into compliance with applicable laws, rules, regulations or codes of which Consultant was aware or should have been aware pursuantto the laws and regulations provision of this Agreement above. Such Additional Services may include, but shall not be limited to:
(a) Separately Bid Portions of Project. Plan preparation and/or administration of work on portions of the Project separately bid. (b) Furniture and Interior Design. Assistance to City, if requested, for the selection of moveable furniture, equipment or articles which are not included in the Construction Documents.
(c) Fault of Contractor. Services caused by delinquency, default or insolvency of contractor, or by major defects in the work of the contractor, provided that any such services made necessary by the failure of Consultant to detect and report such matters when it reasonably should have done so shall not be compensated. (d) Inconsistent Approvals or Instructions. Revisions in drawings, specifications or other documents when such revisions are inconsistent with written approvals or instructions previously given and are due to causes beyond the control of Consultant. (e) Legal Proceedings. Serving as an expert witness on City's behalf or attending legal proceedings to which the Consultant is not a party. (f) Damage Repair. Supervision of repair of damages to any structure. (g) Extra Environmental Services. Additional work required for environmental conditions (e.g. asbestos or site conditions) not already contemplated within the Consultant's services for the Project.
3.9 City Responsibilities. City’s responsibilities shall include the following:
3.9.1 Data and Information. City shall make available to Consultant all necessary data and information concerning the purpose and requirements of the Project, including scheduling and budget limitations, objectives, constraints and criteria. As part of the budget 524
BB&K (2023)
46700.00100\40935196.1
-8-
limitation information, the City shall provide the Consultant with a preliminary construction budget (“City’s Preliminary Construction Budget”).
3.9.2 Project Survey. If required pursuant to the scope of the Project and if requested by Consultant, City shall furnish Consultant with, or direct Consultant to procure at City’s expense, a survey of the Project site prepared by a registered surveyor or civil engineer, any other record documents which shall indicate existing structures, land features, improvements, sewer, water, gas, electrical and utility lines, topographical information and boundary dimensions of the site, and any other such pertinent information.
3.9.3 Bid Phase. Distribute Construction Documents to bidders and conduct the opening and review of bids for the Project.
3.9.4 Testing. Retain consultant(s) to conduct chemical, mechanical, soils, geological or other tests required for proper design of the Project, and furnish such surveys, borings, test pits, and other tests as may be necessary to reveal conditions of the site which must be known to determine soil condition or to ensure the proper development of the required drawings and specifications.
3.9.5 Required Inspections and Tests. Retain consultant(s) to conduct materials testing and inspection or environmental/hazardous materials testing and inspection pursuant to any applicable laws, rules or regulations.
3.9.6 Fees of Reviewing or Licensing Agencies. Directly pay or reimburse the payment of all fees required by any reviewing or licensing agency, or other agency having approval jurisdiction over the Project.
3.9.7 City’s Representative. The City hereby designates the City Manager, or his or her designee, to act as its representative for the performance of this Agreement (“City’s Representative”). City’s Representative shall have the power to act on behalf of the City for all purposes under this Contract. The City Manager hereby designates Tito Haes , Executive Director Public Works, or his or her designee, as the City’s contact for the implementation of the Services hereunder. Contractor shall not accept direction or orders from any person other than the City’s Representative or his or her designee.
3.9.8 Review and Approved Documents. Review all documents submitted by Consultant, including change orders and other matters requiring approval by the City Council or other officials. City shall advise Consultant of decisions pertaining to such documents within a reasonable time after submission, so as not to cause unreasonable delay as provided in the excusable delay provisions of this Agreement above.
3.10 Compensation.
3.10.1 Consultant’s Compensation for Basic Services. City shall pay to Consultant, for the performance of all Services rendered under this Agreement, the total not to exceed amount of One Hundred Fifty Thousand Dollars ($150,000) (“Total Compensation”).
This Total Compensation amount shall be based upon, and may be adjusted according to, the fee schedule and related terms and conditions attached hereto as Exhibit “B” and incorporated herein by reference. The Total Compensation, as may be adjusted upon mutual agreement, shall constitute complete and adequate payment for Services under thisAgreement.
3.10.2 Payment for Additional Services. At any time during the term of this 525
BB&K (2023)
46700.00100\40935196.1
-9-
Agreement, City may request that Consultant perform Additional Services. As used herein, Additional Services means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement. Any additional work in excess of this amount must be approved by the City. If authorized, such Additional Services will be compensated at the rates and in the manner set forth in Exhibit “B” attached hereto and incorporated herein by reference, unless a flat rate or some other form of compensation is mutually agreed upon by the Parties. IfCity requires Consultant to hire consultants to perform any Additional Services, Consultant shall be compensated therefore at the rates and in the manner set forth in Exhibit “B” attached heretoand incorporated herein by reference, unless a flat rate or some other form of compensation is mutually agreed upon by the Parties. City shall have the authority to review and approve the rates of any such consultants. In addition, Consultant shall be reimbursed for any expenses incurred by such consultants pursuant to the terms and conditions of Section 3.10.3.
3.10.3 Reimbursable Expenses. Reimbursable expenses are in addition to compensation for the Services and Additional Services. Consultant shall not be reimbursed for any expenses unless authorized in writing by City, which approval may be evidenced by inclusion in Exhibit “B” attached hereto. Such reimbursable expenses shall include only those expenses which are reasonably and necessarily incurred by Consultant in the interest of the Project.
Consultant shall be required to acquire prior written consent in order to obtain reimbursement for the following: (1) extraordinary transportation expenses incurred in connection with the Project; (2) out-of-town travel expenses incurred in connection with the Project; (3) fees paid for securing approval of authorities having jurisdiction over the Project; (4) bid document duplication costs in excess of $1,000; and (5) other costs, fees and expenses in excess of $1,000.
3.10.4 Payment to Consultant. Consultant’s compensation and reimbursable expenses shall be paid by City to Consultant no more often than monthly. Such periodic payments shall be made based upon the percentage of work completed, and in accordance with the phasing and funding schedule provided in Exhibit “B” and the compensation rates indicated in Exhibit “B” attached hereto and incorporated herein by reference. In order to receive payment, Consultant shall present to City an itemized statement which indicates Services performed, percentage of Services completed, method for computing the amount payable, and the amount to be paid. The statement shall describe the amount of Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement, as well as those expenses for which reimbursement is requested for that statement period. The amount paid to Consultant shall never exceed the percentage amounts authorized by the phasing and funding schedule located in Exhibit “B” attached hereto. City shall, within thirty (30) days of receiving such statement, review the statement and pay all approved charges thereon pursuant to the provisions of Civil Code Section 3320. Disputed amounts shall be resolved by the Parties in a mutually agreeable manner.
Payments made for Additional Services shall be made in installments, not more often than monthly, proportionate to the degree of completion of such services or in such other manner as the Parties shall specify when such services are agreed upon, and in accordance with any authorized fee or rate schedule. In order to receive payment, Consultant shall present to City an itemized statement which indicates the Additional Services performed, percentage of Additional Services completed, method for computing the amount payable, and the amount to be paid. The statement shall describe the amount of Additional Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement. City shall, within thirty (30) days of receiving such statement, review the statement and pay all approved charges thereon pursuant to the provisions of Civil Code 526
BB&K (2023)
46700.00100\40935196.1
-10-
Section 3320. Disputed amounts shall be resolved by the Parties in a mutually agreeable manner.
Upon cancellation or termination of this Agreement, Consultant shall be compensated as set forth in the termination provision herein.
3.10.5 Withholding Payment to Consultant. The City may withhold payment, in whole or in part, to the extent reasonably necessary to protect the City from claims, demands, causes of action, costs, expenses, liabilities, losses, damages, or injuries of any kind to the extent arising out of or caused by the negligence, recklessness, or willful misconduct protected under the indemnification provisions of this Agreement. Failure by City to deduct any sums from a progress payment shall not constitute a waiver of the City’s right to such sums. The City may keep any moneys which would otherwise be payable at any time hereunder and apply the same,or so much as may be necessary therefor, to the payment of any expenses, losses, or damagesas determined by the City, incurred by the City for which Consultant is liable under the Agreementor state law. Payments to the Consultant for compensation and reimbursable expenses due shallnot be contingent on the construction, completion or ultimate success of the Project. Payment tothe Consultant shall not be withheld, postponed, or made contingent upon receipt by the City of offsetting reimbursement or credit from Parties not within the Consultant’s reasonable control.
3.10.6 Prevailing Wages. Consultant is aware of the requirements of California Labor Code Sections 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., (“Prevailing Wage Laws”), which require the payment of prevailing wage rates and the performance of other requirements on certain “public works” and “maintenance” projects. If the Services are being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and if the total compensation is $1,000 or more, Consultant agrees to fully complywith and to require its consultants to fully comply with such Prevailing Wage Laws. City shall provide Consultant with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Consultant shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services available to interested parties upon request, and shall post copies at the Consultant’s principal place of business and at the Project site. It shall be mandatory upon the Consultant and all subconsultants to comply with all California Labor Code provisions, which include but are not limited to prevailing wages (Labor Code Sections 1771, 1774 and 1775), employment of apprentices (Labor Code Section 1777.5), certified payroll records (Labor Code Sections 1771.4and 1776), hours of labor (Labor Code Sections 1813 and 1815) and debarment of contractors and subcontractors (Labor Code Section 1777.1). The requirement to submit certified payroll records directly to the Labor Commissioner under Labor Code section 1771.4 shall not apply to work performed on a public works project that is exempt pursuant to the small project exemption specified in Labor Code Section 1771.4. Consultant shall defend, indemnify and hold the City, itselected officials, officers, employees and agents free and harmless from any claims, liabilities, costs, penalties or interest arising out of any failure or alleged failure of the Consultant or its consultants to comply with the Prevailing Wage Laws. (a) Registration/DIR Compliance. If the Services are being performed as part of an applicable “public works project” of over $25,000 when the project is for construction, alteration, demolition, installation, or repair work, or a public works project of over $15,000 when the project is for maintenance work, in addition to the foregoing, then pursuant to Labor Code sections 1725.5 and 1771.1, the Consultant and all subconsultants performing such Services must be registered with the Department of Industrial Relations (“DIR”). Consultant shall maintain registration for the duration of the Project and require the same of any subconsultants. This project may also be subject to compliance monitoring and enforcement by the DIR. It shall be 527
BB&K (2023)
46700.00100\40935196.1
-11-
Consultant’s sole responsibility to comply with all applicable registration and labor compliance requirements, including the submission of payroll records directly to the DIR. Any stop orders issued by the Department of Industrial Relations against Consultant or any subconsultant that affect Consultant’s performance of services, including any delay, shall be Consultant’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Consultant caused delay and shall not be compensable by the City. Consultant shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the Department of Industrial Relations against Consultant or any subconsultant.
3.11 Notice to Proceed.
Consultant shall not proceed with performance of any Services under this Agreement unless and until the City provides a written notice to proceed.
3.12 Termination, Suspension and Abandonment.
3.12.1 Grounds for Termination; Consultant’s Termination for Cause. City hereby reserves the right to suspend or abandon, at any time and for any reason, all or any portion of the Project and the construction work thereon, or to terminate this Agreement at any time with or without cause. Consultant shall be provided with at least seven (7) days advanced written notice of such suspension, abandonment or termination. In the event of such suspension, abandonment or termination, Consultant shall be paid for Services and reimbursable expenses rendered up to the date of such suspension, abandonment or termination, pursuant to the schedule of payments provided for in this Agreement, less any claims against or damages suffered by City as a result of the default, if any, by Consultant. Consultant hereby expressly waives any and all claims for damages or compensation arising under this Agreement, except as set forth herein, in the event of such suspension, abandonment or termination. Consultant may terminate this Agreement for substantial breach of performance by the City such as failure to make payment to Consultant as provided in this Agreement.
3.12.2 City’s Suspension of Work. If Consultant’s Services are suspended by City, City may require Consultant to resume such Services within ninety (90) days after written notice from City. When the Project is resumed, the Total Compensation and schedule of Services shall be equitably adjusted upon mutual agreement of the City and Consultant.
3.12.3 Documents and Other Data. Upon suspension, abandonment or termination, Consultant shall provide to City all preliminary studies, sketches, working drawings, specifications, computations, and all other Project Documents, as defined below, to which City would have been entitled at the completion of Consultant’s Services under this Agreement. Upon payment of the amount required to be paid to Consultant pursuant to the termination provisions of this Agreement, City shall have the rights, as provided in this Agreement hereinafter, to use such Project Documents prepared by or on behalf of Consultant under this Agreement. Consultant shall make such documents available to City upon request and without additional compensation other than as may be approved as a reimbursable expense.
3.12.4 Employment of other Consultants. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated. 528
BB&K (2023)
46700.00100\40935196.1
-12-
3.13 Ownership and Use of Documents; Confidentiality.
3.13.1 Ownership. All plans, specifications, original or reproducibletransparencies of working drawings and master plans, preliminary sketches, architectural presentation drawings, structural computations, estimates and any other documents prepared pursuant to this Agreement, including, but not limited to, any other works of authorship fixed in any tangible medium of expression such as writings, physical drawings and data magnetically orotherwise recorded on computer diskettes (hereinafter referred to as the “Project Documents”) shall be and remain the property of City. Although the official copyright in all Project Documentsshall remain with the Consultant or other applicable subcontractors or consultants, the Project Documents shall be the property of City whether or not the work for which they were made is executed or completed. Within thirty (30) calendar days following completion of the Project, Consultant shall provide to City copies of all Project Documents required by City. In addition, Consultant shall retain copies of all Project Documents on file for a minimum of fifteen (15) years following completion of the Project, and shall make copies available to City upon the payment ofreasonable duplication costs. Before destroying the Project Documents following this retention period, Consultant shall make a reasonable effort to notify City and provide City with the opportunity to obtain the documents.
3.13.2 Right to Use. Consultant grants to City the right to use and reuse all or part of the Project Documents, at City’s sole discretion and with no additional compensation to Consultant, for the following purposes:
(a) The construction of all or part of this Project.
(b) The repair, renovation, modernization, replacement, reconstruction or expansion of this Project at any time;
(c) The construction of another project by or on behalf of the City for its ownership and use;
City is not bound by this Agreement to employ the services of Consultant in the event such documents are used or reused for these purposes. City shall be able to use or reuse the Project Documents for these purposes without risk of liability to the Consultant or third parties with respect to the condition of the Project Documents, and the use or reuse of the Project Documents for these purposes shall not be construed or interpreted to waive or limit City’s right to recover for latent defects or for errors or omissions of the Consultant.
Any use or reuse by City of the Project Documents on any project other than this Project without employing the services of Consultant shall be at City’s own risk with respect to third parties. If City uses or reuses the Project Documents on any project other than this Project, it shall remove the Consultant’s seal from the Project Documents and hold harmless Consultant and its officers, directors, agents and employees from claims arising out of the negligent use or re-use of the Project Documents on such other project.
3.13.3 License. This Agreement creates a non-exclusive and perpetual license for City to copy, use, modify or reuse any and all Project Documents and any intellectual property rights therein. Consultant shall require any and all subcontractors and consultants to agree in writing that City is granted a non-exclusive and perpetual license for the work of such subcontractors or consultants performed pursuant to this Agreement. 529
BB&K (2023)
46700.00100\40935196.1
-13-
3.13.4 Right to License. Consultant represents and warrants that Consultant has the legal right to license any and all copyrights, designs and other intellectual property embodied in the Project Documents that Consultant prepares or causes to be prepared pursuant to this Agreement. Consultant shall indemnify and hold City harmless pursuant to the indemnification provisions of this Agreement for any breach of this Section. Consultant makes no such representation and warranty in regard to previously prepared designs, plans, specifications, studies, drawings, estimates or other documents that were prepared by design professionals other than Consultant and provided to Consultant by City.
3.13.5 Confidentiality. All Project Documents, either created by or provided to Consultant in connection with the performance of this Agreement, shall be held confidential by Consultant to the extent they are not subject to disclosure pursuant to the Public Records Act. All Project Documents shall not, without the written consent of City, be used or reproduced by Consultant for any purposes other than the performance of the Services. Consultant shall not disclose, cause or facilitate the disclosure of the Project Documents to any person or entity not connected with the performance of the Services or the Project. Nothing furnished to Consultant which is otherwise known to Consultant or is generally known, or has become known, to the related industry shall be deemed confidential. Consultant shall not use City’s name or insignia, photographs of the Project, or any publicity pertaining to the Services or the Project in any magazine, trade paper, newspaper, television or radio production or other similar medium without the written consent of City.
3.14 Indemnification.
3.14.1 To the fullest extent permitted by law, Consultant shall defend (with counsel of City’s choosing), indemnify and hold the City, its officials, officers, employees, volunteers, and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Consultant, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Consultant’s Services, the Project or this Agreement, including without limitation the payment of all damages, expert witness fees and attorney’s fees and other related costs and expenses except such loss or damage caused by the sole negligence or willful misconduct of the City. Consultant's obligation to indemnify shall survive expiration or termination of this Agreement and shall not be restricted to insurance proceeds, if any, received by Consultant, the City, its officials, officers, employees, agents, or volunteers.
3.14.2 If Consultant’s obligation to defend, indemnify, and/or hold harmless arises out of Consultant’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Consultant’s indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Consultant, and, upon Consultant obtaining a final adjudication by a court of competent jurisdiction, Consultant’s liability for such claim, including the cost to defend, shall not exceed the Consultant’s proportionate percentage of fault.
3.15 Insurance. Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this Section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has 530
BB&K (2023)
46700.00100\40935196.1
-14-
secured all insurancerequired under this section.
3.15.1 Types of Insurance Required. As a condition precedent to the effectiveness of this Agreement for work to be performed hereunder, and without limiting the indemnity provisions of the Agreement, Consultant shall, at its expense, procure and maintain infull force and effect for the duration of the Agreement the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Consultant agrees to amend, supplement or endorse the policies to do so.
3.15.2 Additional Insured. The City of Ontario, its officials, officers, employees, agents, and volunteers shall be named as additional insureds on Consultant’s and its subconsultants’ policies of commercial general liability and automobile liability insurance using the endorsements and forms specified herein or exact equivalents.
3.15.3 Commercial General Liability
(a) The Consultant shall take out and maintain, during the performance of all work under this Agreement, in amounts not less than specified herein, Commercial General Liability Insurance, in a form and with insurance companies acceptable to the City. (b) Coverage for Commercial General Liability insurance shall be at least as broad as the following: Insurance Services Office Commercial General Liability coverage (Occurrence Form CG 00 01) or exact equivalent. Commercial General Liability Insurance must include coverage for the following:
(i) Bodily Injury and Property Damage
(ii) Personal Injury/Advertising Injury
(iii) Premises/Operations Liability
(iv) Products/Completed Operations Liability
(v) Aggregate Limits that Apply per Project
(vi) Explosion, Collapse and Underground (UCX) exclusion deleted
(vii) Contractual Liability with respect to this Contract (viii) Broad Form Property Damage
(ix) Independent Consultants Coverage
(c) The policy shall contain no endorsements or provisions limiting coverage for (1) contractual liability; (2) cross liability exclusion for claims or suits by one insured against another; (3) products/completed operations liability; or (4) contain any other exclusion contrary to the Agreement.
(d) The policy shall give City, the City Council and each member of the City Council, its officers, employees, agents and City designated volunteers additional insured status using ISO endorsement forms CG 20 10 10 01 and 20 37 10 01, or endorsements providing 531
BB&K (2023)
46700.00100\40935196.1
-15-
the exact same coverage.
(e) The general liability program may utilize either deductibles or provide coverage excess of a self-insured retention, subject to written approval by the City, and provided that such deductibles shall not apply to the City as an additional insured.
3.15.4 Automobile Liability
(a) At all times during the performance of the work under this Agreement, the Consultant shall maintain Automobile Liability Insurance for bodily injury and property damage including coverage for owned, non-owned and hired vehicles, in a form and with insurance companies acceptable to the City.
(b) Coverage for automobile liability insurance shall be at least as broad as Insurance Services Office Form Number CA 00 01 covering automobile liability (Coverage Symbol 1, any auto).
(c) The policy shall give City, the City Council and each member of the City Council, its officers, employees, agents and City designated volunteers additional insured status.
(d) Subject to written approval by the City, the automobile liability program may utilize deductibles, provided that such deductibles shall not apply to the City as an additional insured, but not a self-insured retention.
3.15.5 Workers’ Compensation/Employer’s Liability
(a) Consultant certifies that he/she is aware of the provisions of Section 3700 of the California Labor Code which requires every employer to be insured against liability for workers’ compensation or to undertake self-insurance in accordance with the provisions of that code, and he/she will comply with such provisions before commencing work under this Agreement.
(b) To the extent Consultant has employees at any time during the term of this Agreement, at all times during the performance of the work under this Agreement, the Consultant shall maintain full compensation insurance for all persons employed directly by him/her to carry out the work contemplated under this Agreement, all in accordance with the “Workers’ Compensation and Insurance Act,” Division IV of the Labor Code of the State of California and any acts amendatory thereof, and Employer’s Liability Coverage in amounts indicated herein. Consultant shall require all subconsultants to obtain and maintain, for the period required by this Agreement, workers’ compensation coverage of the same type and limits as specified in this Section.
3.15.6 Professional Liability (Errors and Omissions)
(a) At all times during the performance of the work under this Agreement the Consultant shall maintain professional liability or Errors and Omissions insurance appropriate to its profession, in a form and with insurance companies acceptable to the City and in an amount indicated herein. This insurance shall be written on a policy form coverage specifically designed to protect against acts, errors or omissions of the Consultant. “Covered Professional Services” as designated in the policy must specifically include work performed under this Agreement. The policy must “pay on behalf of” the insured and must include a provision 532
BB&K (2023)
46700.00100\40935196.1
-16-
establishing the insurer's duty to defend.
3.15.7 Minimum Policy Limits Required
(a) The following insurance limits are required for the Agreement:
Coverage Combined Single Limit
Commercial General Liability $2,000,000 per occurrence/ $4,000,000 aggregate for bodily injury, personal
injury, and property damage
Automobile Liability $2,000,000 per occurrence for bodily injury and property damage
Employer’s Liability $1,000,000 per occurrence
Professional Liability $2,000,000 per claim and aggregate (errors and omissions)
(b) Defense costs shall be payable in addition to the limits. (c) Requirements of specific coverage or limits contained in this Section are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance. Any available coverage shall be provided to the parties required to be named as Additional Insured pursuant to this Agreement.
3.15.8 Evidence Required
(a) Prior to execution of the Agreement, the Consultant shall file with the City evidence of insurance from an insurer or insurers certifying to the coverage of all insurance required herein. Such evidence shall include original copies of the ISO CG 00 01 (or insurer’s equivalent) signed by the insurer’s representative and Certificate of Insurance (Acord Form 25-S or equivalent), together with required endorsements. All evidence of insurance shall be signed by a properly authorized officer, agent, or qualified representative of the insurer and shall certify the names of the insured, any additional insureds, where appropriate, the type and amount of the insurance, the location and operations to which the insurance applies, and the expiration date of such insurance.
3.15.9 Policy Provisions Required
(a) Consultant shall provide the City at least thirty (30) days prior written notice of cancellation of any policy required by this Agreement, except that the Consultantshall provide at least ten (10) days prior written notice of cancellation of any such policy due to nonpayment of premium. If any of the required coverage is cancelled or expires during the termof this Agreement, the Consultant shall deliver renewal certificate(s) including the General Liability Additional Insured Endorsement to the City at least ten (10) days prior to the effective date of cancellation or expiration.
(b) The Commercial General Liability Policy and Automobile Policy shall each contain a provision stating that Consultant’s policy is primary insurance and that any insurance, deductible, or self-insurance maintained by the City, its officials, officers, employees, 533
BB&K (2023)
46700.00100\40935196.1
-17-
agents, or volunteers shall not contribute with this primary insurance. Policies shall contain or be endorsed to contain such provisions.
(c) The retroactive date (if any) of each policy is to be no later than the effective date of this Agreement. Consultant shall maintain such coverage continuously for a period of at least three years after the completion of the work under this Agreement. Consultant shall purchase a one (1) year extended reporting period A) if the retroactive date is advanced past the effective date of this Agreement; B) if the policy is cancelled or not renewed; or C) if thepolicy is replaced by another claims-made policy with a retroactive date subsequent to the effective date of this Agreement.
(d) All required insurance coverages, except for the professional liability coverage, shall contain or be endorsed to waiver of subrogation in favor of the City, its officials, officers, employees, agents, and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these specifications to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants.
(e) The limits set forth herein shall apply separately to each insured against whom claims are made or suits are brought, except with respect to the limits of liability.
Further the limits set forth herein shall not be construed to relieve the Consultant from liability in excess of such coverage, nor shall it limit the Consultant’s indemnification obligations to the City and shall not preclude the City from taking such other actions available to the City under other provisions of the Agreement or law.
3.15.10 Qualifying Insurers
(a) All policies required shall be issued by acceptable insurance companies, as determined by the City, which satisfy the following minimum requirements: Each such policy shall be from a company or companies with a current A.M. Best's rating of no less than A:VII and admitted to transact in the business of insurance in the State of California, or otherwise allowed to place insurance through surplus line brokers under applicable provisions of the California Insurance Code or any federal law.
3.15.11 Additional Insurance Provisions
(a) The foregoing requirements as to the types and limits of insurance coverage to be maintained by Consultant, and any approval of said insurance by the City, is not intended to and shall not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Consultant pursuant to this Agreement, including but not limited to, the provisions concerning indemnification.
(b) If at any time during the life of the Agreement, any policy of insurance required under this Agreement does not comply with these specifications or is canceled and not replaced, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Consultant or City will withhold amounts sufficient to pay premium from Consultant payments. In the alternative, City may cancel this Agreement.
(c) The City may require the Consultant to provide complete copies of all insurance policies in effect for the duration of the Project. 534
BB&K (2023)
46700.00100\40935196.1
-18-
(d) Neither the City nor the City Council, nor any member of the City Council, nor any of the officials, officers, employees, agents or volunteers shall be personally responsible for any liability arising under or by virtue of this Agreement.
3.15.12 Subconsultant Insurance Requirements
(a) Consultant shall not allow any subcontractors or subconsultants to commence work on any subcontract until they have provided evidence satisfactory to the City that they have secured all insurance required under this Section. Policies of commercial general liability insurance provided by such subcontractors or subconsultants shall be endorsed to name the City as an additional insured using ISO form CG 20 38 04 13 or an endorsement providing the exact same coverage. If requested by Consultant, City may approve different scopes or minimum limits of insurance for particular subcontractors or subconsultants.
3.16 Records.
Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to thisAgreement.
Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of five (5) years from the date of final payment under this Agreement.
3.17 Standardized Manufactured Items.
Consultant shall cooperate and consult with City in the use and selection of manufactured items on the Project, including but not limited to, paint, hardware, plumbing, mechanical and electrical equipment, fixtures, roofing materials and floor coverings. All such manufactured items shall be standardized to City’s criteria to the extent such criteria do not interfere with building design.
3.18 Limitation of Agreement.
This Agreement is limited to and includes only the work included in the Project described herein. Any additional or subsequent construction at the site of the Project, or at any other City site, will be covered by, and be the subject of, a separate Agreement for architectural services between City and the Consultant chosen therefor by City.
3.19 Mediation.
Disputes arising from this Agreement may be submitted to mediation if mutually agreeable to the Parties hereto. The type and process of mediation to be utilized shall be subject to the mutual agreement of the Parties.
535
BB&K (2023)
46700.00100\40935196.1
-19-
3.20 Successors and Assigns.
This Agreement shall be binding upon and shall inure to the benefit of the successors in interest, executors, administrators and assigns of each Party to this Agreement. However, Consultant shall not assign or transfer by operation of law or otherwise any or all of its rights, burdens, duties or obligations without the prior written consent of City. Any attempted assignment without such consent shall be invalid and void.
3.21 Asbestos Certification.
Consultant shall certify to City, in writing and under penalty of perjury, that to the best of its knowledge, information and belief no asbestos-containing material or other material deemed to be hazardous by the state or federal government was specified as a building material in any construction document that the Consultant prepares for the Project. Consultant shall require all consultants who prepare any other documents for the Project to submit the same written certification. Consultant shall also assist the City in ensuring that contractors provide City with certification, in writing and under penalty of perjury, that to the best of their knowledge, information and belief no material furnished, installed or incorporated into the Project contains asbestos or any other material deemed to be hazardous by the state or federal government. These certifications shall be part of the final Project submittal. Consultant shall include statements in its specifications that materials containing asbestos or any other material deemed to be hazardous by the state or federal government are not to be included.
3.22 No Third Party Rights.
This Agreement shall not create any rights in, or inure to the benefits of, any third party except as expressly provided herein.
3.23 Governing Law.
This Agreement shall be construed in accordance with, and governed by, the laws of the State of California. Venue shall be in San Bernardino County.
3.24 Exhibits and Recitals.
All exhibits and recitals contained herein and attached hereto are material parts of this Agreement and are incorporated as if fully set forth.
3.25 Severability.
Should any provision in the Agreement be held by a court of competent jurisdiction to be invalid, void, or unenforceable, the remaining provisions shall continue in full force and effect.
3.26 Non-Waiver.
None of the provisions of this Agreement shall be considered waived by either Party, unless such waiver is specifically specified in writing. 536
BB&K (2023)
46700.00100\40935196.1
-20-
3.27 Safety.
Consultant shall execute and maintain its work so as to avoid injury or damage to any person or property. In carrying out its Services, the Consultant shall at all times be in compliance with all applicable local, state and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of its employees, consultant and subcontractors appropriate to the nature of the work and the conditions under which the work is to be performed.
3.28 Harassment Policy.
Consultant shall provide a copy of the City's Harassment Policy to each of its employees assigned to perform the tasks under this Agreement. Consultant shall submit to the City's Personnel Manager a statement signed by each of its employees who are assigned to perform the Services under this Agreement certifying receipt of City's Harassment Policy and certifying that they have read the Harassment Policy. A finding by the City that any of Consultant's employees has harassed a City employee shall be grounds for appropriate discipline, up to and including such employee's removal from performance of this Agreement at City's request.
3.29 Delivery of Notices.
All notices permitted or required under this Agreement shall be given to the respective Parties at the following address, or at such other address as the respective Parties may provide in writing for this purpose:
CITY:
City of Ontario
303 East “B” Street
Ontario, CA 91764
Attn: Adrian Escamilla, Design and Construction
CONSULTANT:
Miller Architectural Corporation
1177 Idaho Street Suite 200
Redlands, Ca 92374
Attn: Gary Miller, Principal
Such notice shall be deemed made when personally delivered or when mailed, forty-eight (48) hours after deposit in the U.S. Mail, first class postage prepaid and addressed to the Party at its applicable address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.
3.30 Time of Essence.
Time is of the essence for each and every provision of this Agreement.
3.31 City’s Right to Employ Other Consultants.
City reserves right to employ other consultants, including designers, in connection with this Project or other project.
537
BB&K (2023)
46700.00100\40935196.1
-21-
3.32 Prohibited Interests.
3.32.1 Solicitation. Consultant maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Consultant, to solicit or secure this Agreement. Further, Consultant warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability.
3.32.2 Conflict of Interest. For the term of this Agreement, no director, official, officer or employee of City, during the term of his or her service with City, shall have any direct interest in this Agreement, or obtain any present or anticipated material benefit arising therefrom.
3.33 Equal Opportunity Employment.
Consultant represents that it is an equal opportunity employer and that it shall not discriminate against any employee or applicant for employment because of race, religion, color, national origin, ancestry, sex, age or any other classification protected by federal or state law.
Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination. Consultant shall also comply with all relevant provisions of City’s minority business enterprise program, affirmative action plan or other related programs or guidelines currently in effect or hereinafter enacted.
3.34 Labor Certification.
By its signature hereunder, Consultant certifies that it is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker’s Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services.
3.35 Subcontracting.
As specified in this Agreement, Consultant shall not subcontract any portion of the Services required by this Agreement, except as expressly stated herein, without prior written approval of City. Subcontracts, if any, shall contain a provision making them subject to each and every provision of this Agreement.
3.36 Supplemental Conditions.
Any supplemental conditions shall be attached as an exhibit to this Agreement, and that exhibit shall be incorporated herein by reference.
3.37 Entire Agreement.
This Agreement, with its exhibits, contains the entire agreement of the Parties hereto, and supersedes any and all other prior or contemporaneous negotiations, understandings and oral or written agreements between the Parties hereto. Each Party acknowledges that no 538
BB&K (2023)
46700.00100\40935196.1
-22-
representations, inducements, promises or agreements have been made by any person which are not incorporated herein, and that any other agreements shall be void. Furthermore, any modification of this Agreement shall only be effective if in writing signed by all Parties hereto.
SIGNATURES ON FOLLOWING PAGE
539
BB&K (2023)
46700.00100\40935196.1
-23-
SIGNATURE PAGE FOR DESIGN SERVICES AGREEMENT
BETWEEN THE CITY OF ONTARIO
AND MILLER ARCHITECURAL
CORPORATION
IN WITNESS WHEREOF, the Parties have executed this Agreement as of the date first written above.
CITY OF ONTARIO MILLER ARCHITECURAL CORPORATION
By:
Its:
Printed Name:
By:
Its:
Printed Name:
[If Corporation, TWO SIGNATURES,
President OR Vice President AND Secretary
OR Treasurer REQUIRED]
Approved By:
Scott Ochoa
City Manager
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:
City Clerk
540
BB&K (2023)
46700.00100\40935196.1
Exhibit A-1
EXHIBIT “A”
SCOPE OF SERVICES
1. GENERAL REQUIREMENTS.
1.1 Basic Services. Consultant agrees to perform all the necessary professional architectural, engineering (e.g. mechanical, electrical, plumbing, structural, site engineering, and any other necessary engineering services mutually agreeable to the Parties) and construction administration services for the Project in a timely and professional manner, consistent with the standards of the profession, including those provided for herein.
1.2 Exclusions from Basic Services. The following services shall be excluded from the basic services listed above: Exclusions will be determined on a project-by-project basis.
1.3 Additional Services. Consultant shall perform the following Additional Services for the Project: Additional Services will be determined on a project by project.
1.4 Communication with City. Consultant shall participate in consultations and conferences with authorized representatives of City and/or other local, regional, or state agencies concerned with the Project, which may be necessary for the completion of the Project or the development of the drawings, specifications and documents in accordance with the applicable standards and requirements of law and the City. Such consultations and conferences shall continue throughout the planning and construction of the Project and the contractor’s warranty period. Consultant shall take direction only from the City’s Representative, or any other representative specifically designated by the City for this Project, including any construction manager hired by the City.
1.5 Coordination and Cooperation with Construction Manager. The City may hire a construction manager to administer and coordinate all or any part of the Project on its behalf. If the City does so, it shall provide a copy of its agreement with the construction manager so that the Consultant will be fully aware of the duties and responsibilities of the construction manager.
The Consultant shall cooperate with the construction manager and respond to any requests or directives authorized by the City to be made or given by the construction manager. The Consultant shall request clarification from the City in writing if the Consultant should have any questions regarding the authority of the construction manager.
2. INITIAL PLANNING PHASE.
During the initial planning phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
2.1 Project Feasibility. Provide advice and assistance to City in determining the feasibility of the Project, analysis of the type and quality of materials and construction to be selected, the site location, and other initial planning matters.
2.2 Meeting Budget and Project Goals. Consultant shall notify City in writing of potential complications, cost overruns, unusual conditions, and general needs that potentially impact the Project budget and time line, including the City’s Preliminary Construction Budget.
Consultant shall use its best judgment in determining the balance between the size, type and 541
BB&K (2023)
46700.00100\40935196.1
Exhibit A-2
quality of construction to achieve a satisfactory solution within the Project’s budget and construction allowance. It shall be the duty of the Consultant to design the Project within budget.
As discussed herein, including in Section 7.3, if the lowest responsive and responsible bid for the Project exceeds the budget by the stated amount, Consultant may be required to make the necessary changes in the drawing and specifications, at its sole cost and expense, to bring the bids within the required budget.
2.3 Permits, Approvals and Authorizations. As indicated in Section 3.5.4 of the Agreement, Consultant shall assist City in securing easements, encroachment permits, rights of way, dedications, infrastructures and road improvements, as well as coordinating with utilities and adjacent property owners.
3. SCHEMATIC PLAN PHASE.
During the schematic plan phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
3.1 Funding Documents. Consultant shall provide a site plan and all other Projectrelated information necessary and required for an application by City to any federal, state, regional, or local agencies for funds to finance the construction Project.
3.2 Schematic Plans. In cooperation with City, Consultant shall prepare preliminary plans and studies, schematic drawings, site utilization plans, and phasing plans showing the scale and relationship of the components of the Project, the plot plan development at the site, and the proposed architectural concept of the buildings (“Schematic Plans”). Consultant shall incorporate the functional requirements of City into the Schematic Plans. The Schematic Plans shall meet all laws, rules and regulations of the State of California. The Schematic Plans shall show all rooms incorporated in each building of the Project in single-line drawings, and shall include all revisions required by City or by any federal, state, regional or local agency having jurisdiction over the Project. All architectural drawings for the Project shall be in a form suitable for reproduction.
3.3 Preliminary Project Budget. Consultant shall use the City’s Preliminary Construction Budget and its own expertise and experience with the Project to establish a preliminary project budget or allowance in a format required by City (“Consultant’s Preliminary Project Budget”). The purpose of the Consultant’s Preliminary Project Budget is to show the probable Project cost in relation to City’s Preliminary Construction Budget and the construction standards of any applicable funding agency. If Consultant perceives site considerations which render the Project expensive or cost prohibitive, Consultant shall disclose such conditions in writing to City immediately. As discussed herein, including in Section 7.3, if the lowest responsive and responsible bid for the Project exceeds the budget by more than the stated amount, Consultant may be required to make the necessary changes in the drawings and specifications, at its sole cost and expense, to bring the bids within the required budget Consultant shall provide a preliminary written time schedule for the performance of all construction work on the Project.
3.4 Copies of Schematic Plans and Other Documents. Consultant, at its own expense, shall provide a complete set of the Schematic Plans described herein for City’s review and approval. Additionally, at City’s expense, Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any additional copies required by City shall be provided at actual cost to City. 542
BB&K (2023)
46700.00100\40935196.1
Exhibit A-3
4. DESIGN DEVELOPMENT PHASE.
During the design development phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
4.1 Design Development Documents. Once City provides Consultant with specific written approval of the Schematic Plans described herein, Consultant shall prepare design development documents consisting of: (1) site and floor plans; (2) elevations; and (3) any other drawings and documents sufficient to fix and describe the types and makeup of materials, as well as the size and character of the Project’s structural, mechanical and electrical systems, and to outline the Project specifications (“Design Development Documents”). The Design Development Documents shall be prepared in sufficient form to present to the City Council for approval.
4.2 Copies of Design Development and Other Documents. Consultant, at its own expense, shall provide a complete set of the Design Development Documents described herein for City’s review and approval. Additionally, at City’s expense, Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any additional copies required by City shall be provided at actual cost to City.
4.3 Updated Project Budget. Consultant shall use its Preliminary Project Budget and expertise and experience with the Project to establish an updated estimate of probable construction costs, containing detail consistent with the Design Development Documents as set forth herein and containing a breakdown based on types of materials and specifications identified herein (“Consultant’s Updated Project Budget”).
4.4 Timetable. Consultant shall provide a written timetable for full and adequate completion of the Project to City.
4.5 Application for Approvals. Consultant shall assist City in applying for and obtaining required approvals from all federal, state, regional or local agencies concerned with the Project. Consultant shall furnish and process all architectural and engineering information required to prepare and process applications to applicable utilities in order to secure priorities and materials, to aid in the construction of the Project and to obtain final Project approval and acceptance by any of the above agencies as may be required.
4.6 Color and Other Aesthetic Issues. Consultant shall provide, for City’s review and approval, a preliminary schedule of all color materials and selections of textures, finishes andother matters involving an aesthetic decision about the Project.
5. FINAL WORKING DRAWINGS AND SPECIFICATIONS.
During the final working drawings and specifications phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
5.1 Final Working Drawings and Specifications. Once City provides Consultant with specific written approval of the Design Development Documents described herein, Consultant shall prepare such complete working drawings and specifications as are necessary for developing complete bids and for properly executing the Project work in an efficient and thorough manner (“Final Working Drawings and Specifications”). Such Final Working Drawings and Specifications shall be developed from the Schematic Plans and Design Development Documents approved by City. The Final Working Drawings and Specifications shall set forth in 543
BB&K (2023)
46700.00100\40935196.1
Exhibit A-4
detail all of the following: (1) the Project construction work to be done; (2) the materials, workmanship, finishes, and equipment required for the architectural, structural, mechanical, and electrical systems; and (3) the utility service connection equipment and site work. As indicated in Section 3.9.2 of the Agreement, City may be requested to supply Consultant with the necessary information to determine the proper location of all improvements on and off site, including record drawings (“as-built drawings”) in City’s possession. Consultant will make a good-faith effort to verify the accuracy of such information by means of a thorough interior and exterior visual survey of site conditions. City shall also make a good-faith effort to verify the accuracy of the as-built drawings and provide any supplemental information to Consultant which may not be shown on the as-built drawings.
5.2 Form. The Final Working Drawings and Specifications must be in such form as will enable Consultant and City to secure the required permits and approvals from all federal, state, regional or local agencies concerned with the Project. In addition, the Final Working Drawings and Specifications must be in such form as will enable City to obtain, by competitive bidding, a responsible and responsive bid within the applicable budgetary limitations and cost standards.
The Final Working Drawings and Specifications shall be clear and legible so that uniform copies may be on standard architectural size paper, properly indexed and numbered, andshall be capable of being clearly copied and assembled in a professional manner by Consultant.
5.3 Approval and Revisions. City shall review, study, and check the Final Working Drawings and Specifications presented to it by Consultant, and request any necessary revisions or obtain any necessary approvals by the City Council, subject to the approval of all federal, state, regional or local agencies concerned with the Project. Consultant shall make all City-requested changes, additions, deletions, and corrections in the Final Working Drawings and Specifications at no additional cost, so long as they are not in conflict with the requirements of public agencies having jurisdiction or prior approval, or inconsistent with earlier City direction or Consultant’s professional judgment. Consultant shall bring any such conflicts and/or inconsistencies to the attention of City. The Parties agree that Consultant, and not the City, possesses the requisite expertise to determine the constructability of the Final Working Drawings and Specifications.
However, the City reserves the right to conduct one or more constructability review processes with the Final Working Drawings and Specifications, and to hire an independent architect or other consultant to perform such reviews. Any such independent constructability review shall be at City’s expense. Consultant shall make all City-requested changes, additions, deletions, and corrections in the Final Working Drawings and Specifications which may result from any constructability review, at no additional cost to the City, so long as they are not in conflict with the requirements of public agencies having jurisdiction or prior approval, or inconsistent with earlier City direction or Consultant’s professional judgment. If such changes, additions, deletions or corrections are inconsistent with prior City direction, Consultant shall make such alterations and be compensated therefore pursuant to the Additional Services provision of this Agreement.
5.4 Costs of Construction. It is understood by Consultant that should the Final Working Drawings and Specifications be ordered by City, City shall specify the sum of money set aside to cover the total cost of construction of the work, exclusive of Consultant’s fees. Should it become evident that the total construction cost will exceed the specified sum, Consultant shall at once present a statement in writing to the City’s Representative setting forth this fact and giving a full statement of the cost estimates on which the conclusion is based.
5.5 Copies of Final Working Drawings and Specifications and Other Documents.
Consultant, at its own expense, shall provide a complete set of the Final Working Drawings and Specifications described herein for City’s review and approval. Additionally, at City’s expense, 544
BB&K (2023)
46700.00100\40935196.1
Exhibit A-5
Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any additional copies required by City shall be provided at actual cost to City.
6. CONSTRUCTION CONTRACT DOCUMENTS.
During the construction contract documents phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
6.1 Bid and Contract Documents. If so required by City, Consultant shall assist City in the completion of all bid and construction documents, including but not limited to, the Notice Inviting Bids, Instructions to Bidders, Contract Bid Forms (including Alternate Bids as requested by City), `Contract, General Conditions, Supplementary General Conditions, Special Conditions, DVBE and other applicable affirmative action documents, Performance Bond, Payment Bond, Escrow Agreement for Security Deposits, and any other certifications and documents required by federal, state and local laws, rules and regulations which may be reasonably required in order to obtain bids responsive to the specifications and drawings. All such documents shall be subject to the approval of City and City’s legal counsel.
6.2 Final Estimate. At the time of delivery of these bid and construction documents, which shall include the Final Working Drawings and Specifications (collectively referred to herein as the “Construction Documents”), Consultant shall provide City with its final estimate of probable construction cost (“Consultant’s Final Estimate”). As discussed herein, including in Section 7.3, it shall be the Consultant’s duty to design the Project within budget.
7. BID PHASE.
During the bid phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
7.1 Reproducible Construction Documents. Once City provides Consultant with specific written approval of the Construction Documents and Consultant’s Final Estimate, Consultant shall provide to City one set of reproducible Construction Documents.
7.2 Distribution of Contract Documents and Review of Bids. Consultant shall assist City in distributing the Construction Documents to bidders and conducting the opening and review of bids for the Project.
7.3 Over Budget. If the apparent lowest responsive and responsible bid on the Project exceeds the Consultant’s Final Estimate by more than five percent (5%), City may request Consultant to amend, at Consultant’s sole cost and expense, the Final Drawings and Specifications in order to rebid the Project and receive a lowest responsive and responsible bid equal to or less than the Consultant’s Final Estimate. All revisions necessary to bring the lowest responsible and responsive bid within the Consultant’s Final Estimate, including any omissions, deferrals or alternates, shall be made in consultation with, and subject to the approval of, the City.
8. CONSTRUCTION PHASE.
During the construction phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
545
BB&K (2023)
46700.00100\40935196.1
Exhibit A-6
8.1 Observation. The Project Consultant shall observe work executed from the Final Working Drawings and Specifications in person, provided that City may, in its discretion, consent to such observation by another competent representative of Consultant.
8.2 General Administration. Consultant shall provide general administration of the Construction Documents and the work performed by the contractors.
8.3 Pre-Construction Meeting. Consultant shall conduct one or more preconstruction meetings, as the City determines is needed for the Project, with all interested Parties.
8.4 Site Visits of Contractor’s Work. Consultant shall conduct site visits to observe each contractors’ work for general conformance with the Construction Documents and with any approved construction schedules or milestones. Such site visits shall be conducted as often as are necessary and appropriate to the stage of construction, according to the City’s sole discretion, but in no event less than weekly.
8.5 Site Visits of Inspector’s Work. Consultant shall conduct site visits to communicate and observe the activities of the City inspectors. Such site visits shall be conducted as often as is mutually acceptable to Consultant and City. Consultant shall direct the City inspectors and the Project contractors to coordinate the preparation of record drawings indicating dimensions and location of all “as-built” conditions, including but not limited to, underground utility lines.
8.6 Coordination of Subconsultants. Consultant shall cause all architects, engineers and other consultants, as may be hired by Consultant or City, to observe the work completed under their disciplines as required, and approve and review all test results for general conformance with the Construction Documents.
8.7 Reports. Consultant shall make regular reports as may be required by applicable federal, state or local laws, rules or regulations, as well as the federal, state, regional or local agencies concerned with the Project.
8.8 Construction Meetings; Minutes. Consultant shall attend all construction meetings and provide written reports/minutes to the City after each construction meeting in order to keep City informed of the progress of the work. Such meetings shall occur at a frequency necessary for the progress of the Project work, according to the City’s sole discretion, but no less than weekly.
8.9 Written Reports. Consultant shall make written reports to City as necessary to inform City of problems arising during construction, changes contemplated as a result of each such problems, and progress of the Project work.
8.10 Written Records. Consultant shall keep accurate written records of the progress and quality of the Project work and the time schedules, and shall advise the contractors and City of any deviations from the time schedule which could delay timely completion of the Project.
8.11 Material and Test Reports. Consultant shall check and process, in a timely manner, all required material and test reports for the Project work. In addition, Consultant shall provide notice of any deficiencies in material or work reflected in such reports, as well as its recommendation for correction of such deficiencies, to the contractors and City. 546
BB&K (2023)
46700.00100\40935196.1
Exhibit A-7
8.12 Review and Response to Submissions. Consultant shall review and respond, in a timely manner, to all schedules, submittals, shop drawings, samples, information requests, change requests, and other submissions of the contractor and subcontractors for compliance with, or alterations and additions to, the Construction Documents. Consultant’s review and response shall be done in such a manner so as to ensure the timely and uninterrupted progress of the Project work.
8.13 Rejection of Work. Consultant shall promptly reject, as discussed with City, work or materials which do not conform to the Construction Documents. Consultant shall immediately notify the City and contractor(s) of such rejections. Consultant shall also have the authority to recommend to the City that additional inspection or testing of the work be performed, whether or not such work is fabricated, installed or completed.
8.14 Substitutions. Consultant shall consult with City, in a timely manner, with regard to substitution of materials, equipment and laboratory reports thereof, prior to the City’s final written approval of such substitutions. Consultant’s consultation shall be done in such a manner so as to ensure the timely and uninterrupted progress of the Project work.
8.15 Revised Documents and Drawings. Consultant shall prepare, at no additional expense to City, all documents and/or drawings made necessary by errors and omissions in the originally approved Construction Documents.
8.16 Change Requests and Material Changes. Consultant shall evaluate and advise City, in a timely manner and in writing, of any change requests and material change(s) which may be requested or necessary in the Project plans and specifications. Consultant shall provide the City with its opinion as to whether such change requests should be approved, denied or revised.
If the City has not hired a construction manager or other person to do so, the Consultant shall prepare and execute all change orders and submit them to the City for authorization. If the City has designated a construction manager or other person to prepare all change orders, the Consultant shall review all change orders prepared by such person, execute them and deliver them to the City for authorization if they meet with the Consultant’s approval, or submit them to the City with recommendations for revision or denial if necessary. Consultant shall not order contractors to make any changes affecting the contract price without approval by City of such a written change order, pursuant to the terms of the Construction Documents. Consultant may order, on its own responsibility and pending City Council approval, changes necessary to meet construction emergencies, if written approval of City’s Representative is first secured.
8.17 Applications for Payment. Consultant shall examine, verify and approve contractor’s applications for payment, and shall issue certificates for payment in amounts approved by the City’s inspector.
8.18 Final Color and Product Selection. Consultant shall coordinate final color and product selection with City’s original design concept.
8.19 Substantial Completion. Consultant shall determine the date of substantial completion, in consultation with the City.
8.20 Punch List. After determining that the Project is substantially complete, Consultant shall participate in the inspection of the Project and shall review all remaining deficiencies and minor items needed to be corrected or completed on the Project, including those identified on the punch list prepared by the contractor (“Punch List Items”). Consultant shall notify 547
BB&K (2023)
46700.00100\40935196.1
Exhibit A-8
contractor in writing that all Punch List Items must be corrected prior to final acceptance of the Project and final payment. Consultant shall also notify City of all Punch List Items.
8.21 Warranties. Consultant shall review materials assembled by the contractor and subcontractors with regard to all written warranties, guarantees, owners’ manuals, instruction books, diagrams, record “as built” drawings, and any other materials required from the contractors and subcontractors pursuant to the Construction Documents. Consultant shall coordinate and provide these materials to the City.
8.22 Certificate of Completion. Consultant shall participate in any further inspections of the Project necessary to issue Consultant’s Certificate of Completion and final certificate for payment.
8.23 Documents for Project Close-Out. Consultant shall cause all other architects, engineers and other consultants, as may be hired by Consultant, to file any and all required documentation with the City or other governmental authorities necessary to close out the Project.
Consultant shall assist the City in obtaining such documentation from all other architects, engineers, or other consultants.
9. AS-BUILT DRAWINGS.
During the as-built drawings phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
9.1 As-Built Drawings and Specifications. Not later than thirty (30) days after substantial completion of the Project, before receipt of final payment, Consultant shall review and forward the Final Working Drawings and Specifications, indicating on them all changes made by change orders or otherwise pursuant to the Construction Documents, as well as all information called for on the specifications, thus producing an “as-built” set of Final Working Drawings and Specifications (“As-Built Drawings and Specifications”). The As-Built Drawings and Specifications shall show, among other things, the location of all concealed pipe, buried conduit runs and other similar elements within the completed Project. Consultant shall personally review and certify that the As-Built Drawings and Specifications are a correct representation of the information supplied to Consultant by any inspectors and the contractor, and shall obtain certifications from any inspectors and the contractor that the drawings are correct.
9.2 Approval. Once City provides Consultant with specific written approval of the AsBuilt Drawings and Specifications, Consultant shall forward to City the complete set of original AsBuilt Drawings and Specifications or a complete set of reproducible duplicate As-Built Drawings and Specifications. The tracing shall be of such quality that clear and legible prints maybe made without appreciable and objectionable loss of detail.
9.3 Documents for Final Payment. Prior to the receipt of Consultant’s final payment, Consultant shall forward to City all of the following: (1) one clear and legible set of reproductions of the computations; (2) the original copy of the specifications; (3) the As-Built Drawings and Specifications as required herein; and (4) Consultant’s Certificate of Completion.
10. WARRANTY PERIOD.
During the warranty period phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
548
BB&K (2023)
46700.00100\40935196.1
Exhibit A-9
10.1 Advice. Consultant shall provide advice to City on apparent deficiencies in the Project during any applicable warranty periods for the Project. 549
BB&K (2023)
46700.00100\40935196.1
Exhibit B-1
EXHIBIT “B”
FEE AND PHASING/FUNDING SCHEDULES
1. FEE SCHEDULE.
Consultant will invoice City on a monthly cycle based on the following fee schedule.
Consultant will include with each invoice a detailed progress report that indicates the amount of budget spent on each phase and the total amount spent against the Total Compensation.
Consultant will inform City regarding any out-of-scope work being performed by Consultant for which Consultant intends to seek compensation from City.
2. PHASING/FUNDING SCHEDULE.
Progress payments towards Total Compensation shall never exceed the following percentages of Total Compensation as of the phase indicated:
550
551
BB&K (2023)
46700.00100\40935196.1
-1-
CITY OF ONTARIO
DESIGN SERVICES AGREEMENT
1. PARTIES AND DATE.
This Agreement is made and entered into as of , by and between the City of Ontario, a municipal corporation organized and operating under the laws of the State of California with its principal place of business at 303 East “B” Street, Ontario, California 91764- 4196, County of San Bernardino, State of California (“City”), and RDC-S111, Inc., a corporation with its principal place of business at 245 E. 3rd St, Long Beach CA 90802 (hereinafter referred to as “Consultant”). City and Consultant are sometimes individually referredto herein as “Party” and collectively as “Parties.”
2. RECITALS.
2.1 City. City is a municipal corporation organized under the laws of the State of California, with power to contract for services necessary to achieve its purpose.
2.2 Consultant. Consultant desires to perform and assume responsibility for the provision of certain professional architectural design services requiredby the City on the terms and conditions set forth in this Agreement. Consultant warrants that it isfully licensed, qualified, and willing to perform the services required by this Agreement; provided, however, that if Consultant is a corporation or other organization, the Project Consultant designated pursuant to Section 3.2, and not the Consultant itself, shall be fully licensed to practiceas an architect in the State of California.
2.3 Project. City desires to engage Consultant to render such services for the On-Call Retail Architect Design Services ("Project") as set forth in this Agreement.
3. TERMS
3.1 Employment of Consultant.
3.1.1 Scope of Services. Consultant promises and agrees to furnish to City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the professional architectural and related services necessary for the full and adequate completion of the Project consistent with the provisions of this Agreement 552
BB&K (2023)
46700.00100\40935196.1
-2-
(hereinafter referred to as “Services”). The Services are more particularly described throughout this Agreement, including Exhibit “A” attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordancewith, this Agreement, any exhibits attached hereto and incorporated herein by reference, and allapplicable local, state and federal laws, rules and regulations. All Services performed by Consultant shall be subject to the sole and discretionary approval of the City, which approval shallnot be unreasonably withheld.
3.1.2 Term. The term of this Agreement shall be from July 16, 2024, to July 16, 2027, The City shall have the unilateral option, at its sole discretion, to renew this Agreement automatically for no more than two additional one-year terms unless earlier terminated as provided herein. Consultant shall complete the Services within the term of agreement and shall meet any other established scheduled and deadlines.
3.2 Project Consultant; Key Personnel.
3.2.1 Retail Architect. Consultant shall name a specific individual to act as Project Consultant, subject to the approval of City. Consultanthereby designates Mitra Esfandiari to act as the Retail Architect for the Project. The Architect shall: (1) maintain oversight of the Services; (2) have full authority to represent and act on behalf of the Consultant for all purposes under this Agreement; (3) supervise and direct the Services using his or her best skill and attention; (4) be responsible for the means, methods, techniques, sequences and procedures used for the Services; (5) adequately coordinate all portions of the Services; and (6) act as principal contact with y and all contractors, consultants, engineers and inspectors on the Project. Any change in the Retail Architect shall be subject to the City’s prior written approval, which approval shall not be unreasonably withheld. The new Retail Architect shall be of at least equal competence as the prior Retail Architect. In the event that City and Consultant cannotagree as to the substitution of a new Retail Architect. City shall be entitled to terminate this Agreement for cause.
3.2.2 Key Personnel. In addition to the Retail Architect, Consultant has represented to the City that certain additional key personnel, engineers and consultants will perform the Services under this Agreement. Should one or more of such personnel, engineers or consultants become unavailable, Consultant may substitute others of atleast equal competence upon written approval of the City. In the event that City and Consultant cannot agree as to the substitution of key personnel, engineers or consultants, City shall be entitled to terminate this Agreement for cause. The key additional personnel, engineers and consultants for performance of this Agreement are as follows: Mitra Esfandiari, Principal
3.3 Hiring of Consultants and Personnel.
3.3.1 Right to Hire or Employ. Consultant shall have the option, unless City objects in writing after notice, to employ at its expense architects, engineers, experts or other consultants qualified and licensed to render services in connection with the planning and/or administration of the Project, and to delegate to them such duties as Consultant may delegate without relieving Consultant from administrative or other responsibility under this Agreement.
Consultant shall be responsible for the coordination and cooperation of Consultant’s architects, engineers, experts or other consultants. All consultants, including changes in consultants, shall be subject to approval by City in its sole and reasonable discretion. Consultant shall notify City of the identity of all consultants at least fourteen (14) days prior to their commencement of work to allow City to review their qualifications and approve to their participation on the Project in its 553
BB&K (2023)
46700.00100\40935196.1
-3-
sole and reasonable discretion.
3.3.2 Qualification and License. All architects, engineers, experts and other consultants retained by Consultant in performance of this Agreement shall be qualified to perform the Services assigned to them, and shall be licensed to practice in their respective professions, where required by law.
3.3.3 Standards and Insurance. All architects, engineers, experts and other consultants hired by Consultant shall be required to meet all of the same standards and insurance requirements set forth in this Agreement, unless other standards or requirements are approved by the City in writing. Unless changes are approved in writing by the City, Consultant’s agreements with its consultants shall contain a provision making them subject to all provisions stipulated in this Agreement.
3.3.4 Assignments or Staff Changes. Consultant shall promptly obtain written City approval of any assignment, reassignment or replacement of such architects, engineers, experts and consultants, or of other staff changes of key personnel working on the Project. As provided in the Agreement, any changes in Consultant’s consultants and key personnel shall be subject to approval by City.
3.3.5 Draftsman and Clerical Support. Draftsmen and clerical personnel shall be retained by Consultant at Consultant’s sole expense.
3.4 Standard of Care.
3.4.1 Standard of Care. Consultant shall perform all Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals qualified to perform the Services in the same discipline in the State of California, and shall be responsible to City for damages sustained by the City and delays to the Project as specified in the indemnification provision of this Agreement. Without limiting the foregoing, Consultant shall be fully responsible to the City for any increased costs incurred by the City as a result of any such delays in the design or construction of the Project. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services. Consultant warrants and represents that all of its employees, architects, engineers, experts and other consultants shall have sufficient skill and experience to perform the Services assigned to them. Finally, Consultant represents that it, its employees, architects, engineers, experts and other consultants have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services assigned to or rendered by them and that such licenses and approvals shall be maintained throughout the term of this Agreement. As provided for in the indemnification provisions of this Agreement, Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant’s failure to comply with the standard of care provided for herein.
3.4.2 Performance of Employees. Any employee or consultant who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee or consultant who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed from the Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.
554
BB&K (2023)
46700.00100\40935196.1
-4-
3.5 Laws and Regulations.
3.5.1 Knowledge and Compliance. Consultant shall keep itself fully informed of and in compliance with all applicable local, state and federal laws, rules and regulations in any manner affecting the performance of the Services or the Project, and shall give all notices required of the Consultant by law. Consultant shall be liable, pursuant to the standard of care and indemnification provisions of this Agreement, for all violations of such laws and regulations in connection with its Services. Consultant shall defend, indemnify and hold City, its officials, officers, employees and agents free and harmless, pursuant to the indemnification provisions of this Agreement, from any claim or liability arising out of any failure or alleged failure to comply with such laws, rules or regulations.
3.5.2 Drawings and Specifications. Consultant shall cause all drawings and specifications to conform to any applicable requirements of federal, state and local laws, rules and regulations, including the Uniform Building Code, in effect as of the time the drawings and specifications are prepared or revised during the latest phase of the Services described in Exhibit “A” attached hereto. Any significant revisions made necessary by changes in such laws, rules and regulations after this time may be compensated as Additional Services which were not knownor reasonably should not have been known by Consultant. Consultant shall cause the necessary copies of such drawings and specifications to be filed with any governmental bodies with approval jurisdiction over the Project, in accordance with the Services described in Exhibit “A” attached hereto. For the preparation of all such drawings and specifications, the Consultant shall use Computer Aided Design Drafting (“CADD”) (e.g., AutoCAD) or other technology acceptable to the Consultant and City.
3.5.3 Americans with Disabilities Act. Consultant will use its best professional efforts to interpret all applicable federal, state and local laws, rules and regulations with respect to access, including those of the Americans with Disabilities Act (“ADA”). Consultant shall inform City of the existence of inconsistencies of which it is aware or reasonably should be aware between federal and state accessibility laws, rules and regulations, as well as any other issues which are subject to conflicting interpretations of the law, and shall provide the City with its interpretation of such inconsistencies and conflicting interpretations. Unless Consultant brings such inconsistencies and conflicting interpretations to the attention of the City and requests City’s direction on how to proceed, the Consultant’s interpretation of such inconsistencies and conflicting interpretations shall be the sole responsibility and liability of Consultant, and the Consultant shall correct all plans, specifications and other documents prepared for the Project at no additional cost if its interpretations are shown to be incorrect. In the event that the Consultant request’s City’s direction on how to proceed with respect to any inconsistent and/or conflicting interpretation, the Consultant shall be responsible to the City only pursuant to the indemnification provisions of this Agreement.
3.5.4 Permits, Approvals and Authorizations. Consultant shall provide City with a list of all permits, approvals or other authorizations required for the Project from all federal, stateor local governmental bodies with approval jurisdiction over the Project. Consultant shall then assist the City in obtaining all such permits, approvals and other authorizations. The costs of such permits, approvals and other authorizations shall be paid by the City.
3.5.5 Water Quality Management and Compliance. Consultant shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Services including, without limitation, all applicable provisions of the City’s ordinances 555
BB&K (2023)
46700.00100\40935196.1
-5-
regulating water quality and storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251 et seq.); the California Porter-Cologne Water Quality Control Act (Cal Water Code §§ 13000- 14950); and any and all regulations, policies, or permits issued pursuant to any such authority.
Consultant shall additionally comply with the lawful requirements of the City, and any other municipality, drainage district, or other local agency with jurisdiction over the location where the Services are to be conducted, regulating water quality and storm water discharges. Failure to comply with laws, regulations, and ordinances listed in this Section is a violation of federal and state law.
3.6 Independent Contractor.
3.6.1 Control and Payment of Subordinates. City retains Consultant on an independent contractor basis and Consultant is not an employee of City. Consultant is not an employee for state tax, federal tax or any other purpose, and is not entitled to the rights or benefits afforded to City’s employees. Any additional personnel performing the Services under this Agreement on behalf of Consultant shall also not be employees of City, and shall at all times be under Consultant’s exclusive direction and control. Consultant shall pay all wages, salaries, and other amounts due such personnel in connection with their performance of Services under this Agreement and as required by law. Consultant shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers’ compensation insurance.
3.7 Schedule of Services.
3.7.1 Consultant Services. Consultant shall fully and adequately complete the Services described in this Agreement and in Exhibit “A” attached hereto and incorporated herein by reference.
3.7.2 Timely Performance Standard. Consultant shall perform all Services hereunder as expeditiously as is consistent with professional skill and care, as well as the orderly progress of the Project work so as not to be the cause, in whole or in part, of delays in the completion of the Project or in the achievement of any Project milestones, as provided herein.
Specifically, Consultant shall perform its Services so as to allow for the full and adequate completion of the Project within the time required by the City and within any completion schedules adopted for the Project. Consultant agrees to coordinate with City’s staff, contractors and consultants in the performance of the Services, and shall be available to City’s staff, contractors and consultants at all reasonable times.
3.7.3 Performance Schedule. Consultant shall prepare an estimated time schedule for the performance of Consultant’s Services, to be adjusted as the Project proceeds.
Such schedule shall be subject to the City’s review and approval, which approval shall not be unreasonably withheld, and shall include allowances for periods of time required for City’s review and approval of submissions, and for approvals of authorities having jurisdiction over Project approval and funding. If City and Consultant cannot mutually agree on a performance schedule, City shall have the authority to immediately terminate this Agreement. The schedule shall not be exceeded by Consultant without the prior written approval of City. If the Consultant’s Services are not completed within the time provided by the agreed upon performance schedule, or any milestones established therein, it is understood, acknowledged and agreed that the City will suffer damage for which the Consultant will be responsible.
556
BB&K (2023)
46700.00100\40935196.1
-6-
3.7.4 Excusable Delays. Any delays in Consultant’s work caused by the following may be added to the time for completion of any obligations of Consultant: (1) the actionsof City or its employees; (2) the actions of those in direct contractual relationship with City; (3) theactions of any governmental agency having jurisdiction over the Project; (4) the actions of any parties not within the reasonable control of the Consultant; and (5) any Force Majeure Event (asdefined herein) or other unforeseen occurrence not due to any fault or negligence on the part of Consultant. Neither the City nor the Consultant shall be liable for damages, liquidated or otherwise, to the other on account of such delays.
3.7.5 Force Majeure Events. Neither City nor Consultant shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the non-performing Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Consultant and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the Services and Agreement. Should a Force Majeure Event occur, the nonperforming Party shall, within fifteen (15) calendar days of the beginning of an Force Majeure Event, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events shall not entitle Consultant to any additional compensation. Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement.
3.7.6 Request for Excusable Delay Credit. The Consultant shall, within fifteen (15) calendar days of the beginning of any excusable delay, notify the City in writing of the causes of delay (unless City grants in writing a further period of time to file such notice prior to the date of final payment under the Agreement). City will then ascertain the facts and the extent of the delay, and grant an extension of time for completing the Services when, in its sole judgment, the findings of fact justify such an extension. The City’s findings of fact thereon shall be final and conclusive on the Parties. Extensions of time shall apply only to that portion of the Services affected by the delay and shall not apply to other portions of the Services not so affected. The sole remedy of Consultant for extensions of time shall be an extension of the performance time at no cost to the City. If Additional Services are required as a result of an excusable delay, the Parties shall mutually agree thereto pursuant to the Additional Services provision of this Agreement. Should Consultant make an application for an extension of time, Consultant shall submit evidence that the insurance policies required by this Agreement remain in effect during the requested additional period of time.
3.8 Additional Services.
3.8.1 Request for Services. At City’s request, Consultant may be asked to perform services not otherwise included in this Agreement, not included within the basic services listed in Exhibit “A” attached hereto, and/or not customarily furnished in accordance with generally 557
BB&K (2023)
46700.00100\40935196.1
-7-
accepted architectural practice.
3.8.2 Definition. As used herein, “Additional Services” mean: (1) any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary for the Consultant to perform at the execution of this Agreement; or (2) any work listed as Additional Services in Exhibit “A” attached hereto. Consultant shall not perform, nor be compensated for, Additional Services without prior written authorization from City and without an agreement between the City and Consultant as to the compensation to be paid for such services. City shall pay Consultant for any approved Additional Services, pursuant to the compensation provisions herein, so long as such services are not made necessary through the fault of Consultant pursuant to the indemnification provision of this Agreement.
3.8.3 Examples of Additional Services. Such Additional Services shall notinclude any redesign or revisions to drawings, specifications or other documents when such revisions are necessary in order to bring such documents into compliance with applicable laws, rules, regulations or codes of which Consultant was aware or should have been aware pursuantto the laws and regulations provision of this Agreement above. Such Additional Services may include, but shall not be limited to:
(a) Separately Bid Portions of Project. Plan preparation and/or administration of work on portions of the Project separately bid. (b) Furniture and Interior Design. Assistance to City, if requested, for the selection of moveable furniture, equipment or articles which are not included in the Construction Documents.
(c) Fault of Contractor. Services caused by delinquency, default or insolvency of contractor, or by major defects in the work of the contractor, provided that any such services made necessary by the failure of Consultant to detect and report such matters when it reasonably should have done so shall not be compensated. (d) Inconsistent Approvals or Instructions. Revisions in drawings, specifications or other documents when such revisions are inconsistent with written approvals or instructions previously given and are due to causes beyond the control of Consultant. (e) Legal Proceedings. Serving as an expert witness on City's behalf or attending legal proceedings to which the Consultant is not a party. (f) Damage Repair. Supervision of repair of damages to any structure. (g) Extra Environmental Services. Additional work required for environmental conditions (e.g. asbestos or site conditions) not already contemplated within the Consultant's services for the Project.
3.9 City Responsibilities. City’s responsibilities shall include the following:
3.9.1 Data and Information. City shall make available to Consultant all necessary data and information concerning the purpose and requirements of the Project, including scheduling and budget limitations, objectives, constraints and criteria. As part of the budget limitation information, the City shall provide the Consultant with a preliminary construction budget (“City’s Preliminary Construction Budget”).
558
BB&K (2023)
46700.00100\40935196.1
-8-
3.9.2 Project Survey. If required pursuant to the scope of the Project and if requested by Consultant, City shall furnish Consultant with, or direct Consultant to procure at City’s expense, a survey of the Project site prepared by a registered surveyor or civil engineer, any other record documents which shall indicate existing structures, land features, improvements, sewer, water, gas, electrical and utility lines, topographical information and boundary dimensions of the site, and any other such pertinent information.
3.9.3 Bid Phase. Distribute Construction Documents to bidders and conduct the opening and review of bids for the Project.
3.9.4 Testing. Retain consultant(s) to conduct chemical, mechanical, soils, geological or other tests required for proper design of the Project, and furnish such surveys, borings, test pits, and other tests as may be necessary to reveal conditions of the site which must be known to determine soil condition or to ensure the proper development of the required drawings and specifications.
3.9.5 Required Inspections and Tests. Retain consultant(s) to conduct materials testing and inspection or environmental/hazardous materials testing and inspection pursuant to any applicable laws, rules or regulations.
3.9.6 Fees of Reviewing or Licensing Agencies. Directly pay or reimburse the payment of all fees required by any reviewing or licensing agency, or other agency having approval jurisdiction over the Project.
3.9.7 City’s Representative. The City hereby designates the City Manager, or his or her designee, to act as its representative for the performance of this Agreement (“City’s Representative”). City’s Representative shall have the power to act on behalf of the City for all purposes under this Contract. The City Manager hereby designates Tito Haes , Executive Director Public Works, or his or her designee, as the City’s contact for the implementation of the Services hereunder. Contractor shall not accept direction or orders from any person other than the City’s Representative or his or her designee.
3.9.8 Review and Approved Documents. Review all documents submitted by Consultant, including change orders and other matters requiring approval by the City Council or other officials. City shall advise Consultant of decisions pertaining to such documents within a reasonable time after submission, so as not to cause unreasonable delay as provided in the excusable delay provisions of this Agreement above.
3.10 Compensation.
3.10.1 Consultant’s Compensation for Basic Services. City shall pay to Consultant, for the performance of all Services rendered under this Agreement, the total not to exceed amount of One Hundred Fifty Thousand Dollars ($150,000) (“Total Compensation”).
This Total Compensation amount shall be based upon, and may be adjusted according to, the fee schedule and related terms and conditions attached hereto as Exhibit “B” and incorporated herein by reference. The Total Compensation, as may be adjusted upon mutual agreement, shall constitute complete and adequate payment for Services under thisAgreement.
3.10.2 Payment for Additional Services. At any time during the term of this Agreement, City may request that Consultant perform Additional Services. As used herein, Additional Services means any work which is determined by City to be necessary for the proper 559
BB&K (2023)
46700.00100\40935196.1
-9-
completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement. Any additional work in excess of this amount must be approved by the City. If authorized, such Additional Services will be compensated at the rates and in the manner set forth in Exhibit “B” attached hereto and incorporated herein by reference, unless a flat rate or some other form of compensation is mutually agreed upon by the Parties. IfCity requires Consultant to hire consultants to perform any Additional Services, Consultant shall be compensated therefore at the rates and in the manner set forth in Exhibit “B” attached heretoand incorporated herein by reference, unless a flat rate or some other form of compensation is mutually agreed upon by the Parties. City shall have the authority to review and approve the rates of any such consultants. In addition, Consultant shall be reimbursed for any expenses incurred by such consultants pursuant to the terms and conditions of Section 3.10.3.
3.10.3 Reimbursable Expenses. Reimbursable expenses are in addition to compensation for the Services and Additional Services. Consultant shall not be reimbursed for any expenses unless authorized in writing by City, which approval may be evidenced by inclusion in Exhibit “B” attached hereto. Such reimbursable expenses shall include only those expenses which are reasonably and necessarily incurred by Consultant in the interest of the Project.
Consultant shall be required to acquire prior written consent in order to obtain reimbursement for the following: (1) extraordinary transportation expenses incurred in connection with the Project; (2) out-of-town travel expenses incurred in connection with the Project; (3) fees paid for securing approval of authorities having jurisdiction over the Project; (4) bid document duplication costs in excess of $1,000; and (5) other costs, fees and expenses in excess of $1,000.
3.10.4 Payment to Consultant. Consultant’s compensation and reimbursable expenses shall be paid by City to Consultant no more often than monthly. Such periodic payments shall be made based upon the percentage of work completed, and in accordance with the phasing and funding schedule provided in Exhibit “B” and the compensation rates indicated in Exhibit “B” attached hereto and incorporated herein by reference. In order to receive payment, Consultant shall present to City an itemized statement which indicates Services performed, percentage of Services completed, method for computing the amount payable, and the amount to be paid. The statement shall describe the amount of Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement, as well as those expenses for which reimbursement is requested for that statement period. The amount paid to Consultant shall never exceed the percentage amounts authorized by the phasing and funding schedule located in Exhibit “B” attached hereto. City shall, within thirty (30) days of receiving such statement, review the statement and pay all approved charges thereon pursuant to the provisions of Civil Code Section 3320. Disputed amounts shall be resolved by the Parties in a mutually agreeable manner.
Payments made for Additional Services shall be made in installments, not more often than monthly, proportionate to the degree of completion of such services or in such other manner as the Parties shall specify when such services are agreed upon, and in accordance with any authorized fee or rate schedule. In order to receive payment, Consultant shall present to City an itemized statement which indicates the Additional Services performed, percentage of Additional Services completed, method for computing the amount payable, and the amount to be paid. The statement shall describe the amount of Additional Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement. City shall, within thirty (30) days of receiving such statement, review the statement and pay all approved charges thereon pursuant to the provisions of Civil Code Section 3320. Disputed amounts shall be resolved by the Parties in a mutually agreeable manner. 560
BB&K (2023)
46700.00100\40935196.1
-10-
Upon cancellation or termination of this Agreement, Consultant shall be compensated as set forth in the termination provision herein.
3.10.5 Withholding Payment to Consultant. The City may withhold payment, in whole or in part, to the extent reasonably necessary to protect the City from claims, demands, causes of action, costs, expenses, liabilities, losses, damages, or injuries of any kind to the extent arising out of or caused by the negligence, recklessness, or willful misconduct protected under the indemnification provisions of this Agreement. Failure by City to deduct any sums from a progress payment shall not constitute a waiver of the City’s right to such sums. The City may keep any moneys which would otherwise be payable at any time hereunder and apply the same,or so much as may be necessary therefor, to the payment of any expenses, losses, or damagesas determined by the City, incurred by the City for which Consultant is liable under the Agreementor state law. Payments to the Consultant for compensation and reimbursable expenses due shallnot be contingent on the construction, completion or ultimate success of the Project. Payment tothe Consultant shall not be withheld, postponed, or made contingent upon receipt by the City of offsetting reimbursement or credit from Parties not within the Consultant’s reasonable control.
3.10.6 Prevailing Wages. Consultant is aware of the requirements of California Labor Code Sections 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., (“Prevailing Wage Laws”), which require the payment of prevailing wage rates and the performance of other requirements on certain “public works” and “maintenance” projects. If the Services are being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and if the total compensation is $1,000 or more, Consultant agrees to fully complywith and to require its consultants to fully comply with such Prevailing Wage Laws. City shall provide Consultant with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Consultant shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services available to interested parties upon request, and shall post copies at the Consultant’s principal place of business and at the Project site. It shall be mandatory upon the Consultant and all subconsultants to comply with all California Labor Code provisions, which include but are not limited to prevailing wages (Labor Code Sections 1771, 1774 and 1775), employment of apprentices (Labor Code Section 1777.5), certified payroll records (Labor Code Sections 1771.4and 1776), hours of labor (Labor Code Sections 1813 and 1815) and debarment of contractors and subcontractors (Labor Code Section 1777.1). The requirement to submit certified payroll records directly to the Labor Commissioner under Labor Code section 1771.4 shall not apply to work performed on a public works project that is exempt pursuant to the small project exemption specified in Labor Code Section 1771.4. Consultant shall defend, indemnify and hold the City, itselected officials, officers, employees and agents free and harmless from any claims, liabilities, costs, penalties or interest arising out of any failure or alleged failure of the Consultant or its consultants to comply with the Prevailing Wage Laws. (a) Registration/DIR Compliance. If the Services are being performed as part of an applicable “public works project” of over $25,000 when the project is for construction, alteration, demolition, installation, or repair work, or a public works project of over $15,000 when the project is for maintenance work, in addition to the foregoing, then pursuant to Labor Code sections 1725.5 and 1771.1, the Consultant and all subconsultants performing such Services must be registered with the Department of Industrial Relations (“DIR”). Consultant shall maintain registration for the duration of the Project and require the same of any subconsultants. This project may also be subject to compliance monitoring and enforcement by the DIR. It shall be Consultant’s sole responsibility to comply with all applicable registration and labor compliance 561
BB&K (2023)
46700.00100\40935196.1
-11-
requirements, including the submission of payroll records directly to the DIR. Any stop orders issued by the Department of Industrial Relations against Consultant or any subconsultant that affect Consultant’s performance of services, including any delay, shall be Consultant’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Consultant caused delay and shall not be compensable by the City. Consultant shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the Department of Industrial Relations against Consultant or any subconsultant.
3.11 Notice to Proceed.
Consultant shall not proceed with performance of any Services under this Agreement unless and until the City provides a written notice to proceed.
3.12 Termination, Suspension and Abandonment.
3.12.1 Grounds for Termination; Consultant’s Termination for Cause. City hereby reserves the right to suspend or abandon, at any time and for any reason, all or any portion of the Project and the construction work thereon, or to terminate this Agreement at any time with or without cause. Consultant shall be provided with at least seven (7) days advanced written notice of such suspension, abandonment or termination. In the event of such suspension, abandonment or termination, Consultant shall be paid for Services and reimbursable expenses rendered up to the date of such suspension, abandonment or termination, pursuant to the schedule of payments provided for in this Agreement, less any claims against or damages suffered by City as a result of the default, if any, by Consultant. Consultant hereby expressly waives any and all claims for damages or compensation arising under this Agreement, except as set forth herein, in the event of such suspension, abandonment or termination. Consultant may terminate this Agreement for substantial breach of performance by the City such as failure to make payment to Consultant as provided in this Agreement.
3.12.2 City’s Suspension of Work. If Consultant’s Services are suspended by City, City may require Consultant to resume such Services within ninety (90) days after written notice from City. When the Project is resumed, the Total Compensation and schedule of Services shall be equitably adjusted upon mutual agreement of the City and Consultant.
3.12.3 Documents and Other Data. Upon suspension, abandonment or termination, Consultant shall provide to City all preliminary studies, sketches, working drawings, specifications, computations, and all other Project Documents, as defined below, to which City would have been entitled at the completion of Consultant’s Services under this Agreement. Upon payment of the amount required to be paid to Consultant pursuant to the termination provisions of this Agreement, City shall have the rights, as provided in this Agreement hereinafter, to use such Project Documents prepared by or on behalf of Consultant under this Agreement. Consultant shall make such documents available to City upon request and without additional compensation other than as may be approved as a reimbursable expense.
3.12.4 Employment of other Consultants. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated. 562
BB&K (2023)
46700.00100\40935196.1
-12-
3.13 Ownership and Use of Documents; Confidentiality.
3.13.1 Ownership. All plans, specifications, original or reproducibletransparencies of working drawings and master plans, preliminary sketches, architectural presentation drawings, structural computations, estimates and any other documents prepared pursuant to this Agreement, including, but not limited to, any other works of authorship fixed in any tangible medium of expression such as writings, physical drawings and data magnetically orotherwise recorded on computer diskettes (hereinafter referred to as the “Project Documents”) shall be and remain the property of City. Although the official copyright in all Project Documentsshall remain with the Consultant or other applicable subcontractors or consultants, the Project Documents shall be the property of City whether or not the work for which they were made is executed or completed. Within thirty (30) calendar days following completion of the Project, Consultant shall provide to City copies of all Project Documents required by City. In addition, Consultant shall retain copies of all Project Documents on file for a minimum of fifteen (15) years following completion of the Project, and shall make copies available to City upon the payment ofreasonable duplication costs. Before destroying the Project Documents following this retention period, Consultant shall make a reasonable effort to notify City and provide City with the opportunity to obtain the documents.
3.13.2 Right to Use. Consultant grants to City the right to use and reuse all or part of the Project Documents, at City’s sole discretion and with no additional compensation to Consultant, for the following purposes:
(a) The construction of all or part of this Project.
(b) The repair, renovation, modernization, replacement, reconstruction or expansion of this Project at any time;
(c) The construction of another project by or on behalf of the City for its ownership and use;
City is not bound by this Agreement to employ the services of Consultant in the event such documents are used or reused for these purposes. City shall be able to use or reuse the Project Documents for these purposes without risk of liability to the Consultant or third parties with respect to the condition of the Project Documents, and the use or reuse of the Project Documents for these purposes shall not be construed or interpreted to waive or limit City’s right to recover for latent defects or for errors or omissions of the Consultant.
Any use or reuse by City of the Project Documents on any project other than this Project without employing the services of Consultant shall be at City’s own risk with respect to third parties. If City uses or reuses the Project Documents on any project other than this Project, it shall remove the Consultant’s seal from the Project Documents and hold harmless Consultant and its officers, directors, agents and employees from claims arising out of the negligent use or re-use of the Project Documents on such other project.
3.13.3 License. This Agreement creates a non-exclusive and perpetual license for City to copy, use, modify or reuse any and all Project Documents and any intellectual property rights therein. Consultant shall require any and all subcontractors and consultants to agree in writing that City is granted a non-exclusive and perpetual license for the work of such subcontractors or consultants performed pursuant to this Agreement. 563
BB&K (2023)
46700.00100\40935196.1
-13-
3.13.4 Right to License. Consultant represents and warrants that Consultant has the legal right to license any and all copyrights, designs and other intellectual property embodied in the Project Documents that Consultant prepares or causes to be prepared pursuant to this Agreement. Consultant shall indemnify and hold City harmless pursuant to the indemnification provisions of this Agreement for any breach of this Section. Consultant makes no such representation and warranty in regard to previously prepared designs, plans, specifications, studies, drawings, estimates or other documents that were prepared by design professionals other than Consultant and provided to Consultant by City.
3.13.5 Confidentiality. All Project Documents, either created by or provided to Consultant in connection with the performance of this Agreement, shall be held confidential by Consultant to the extent they are not subject to disclosure pursuant to the Public Records Act. All Project Documents shall not, without the written consent of City, be used or reproduced by Consultant for any purposes other than the performance of the Services. Consultant shall not disclose, cause or facilitate the disclosure of the Project Documents to any person or entity not connected with the performance of the Services or the Project. Nothing furnished to Consultant which is otherwise known to Consultant or is generally known, or has become known, to the related industry shall be deemed confidential. Consultant shall not use City’s name or insignia, photographs of the Project, or any publicity pertaining to the Services or the Project in any magazine, trade paper, newspaper, television or radio production or other similar medium without the written consent of City.
3.14 Indemnification.
3.14.1 To the fullest extent permitted by law, Consultant shall defend (with counsel of City’s choosing), indemnify and hold the City, its officials, officers, employees, volunteers, and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Consultant, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Consultant’s Services, the Project or this Agreement, including without limitation the payment of all damages, expert witness fees and attorney’s fees and other related costs and expenses except such loss or damage caused by the sole negligence or willful misconduct of the City. Consultant's obligation to indemnify shall survive expiration or termination of this Agreement and shall not be restricted to insurance proceeds, if any, received by Consultant, the City, its officials, officers, employees, agents, or volunteers.
3.14.2 If Consultant’s obligation to defend, indemnify, and/or hold harmless arises out of Consultant’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Consultant’s indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Consultant, and, upon Consultant obtaining a final adjudication by a court of competent jurisdiction, Consultant’s liability for such claim, including the cost to defend, shall not exceed the Consultant’s proportionate percentage of fault.
3.15 Insurance. Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this Section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has
564
BB&K (2023)
46700.00100\40935196.1
-14-
provided evidence satisfactory to the City that the subconsultant has secured all insurance required under this section.
3.15.1 Types of Insurance Required. As a condition precedent to the effectiveness of this Agreement for work to be performed hereunder, and without limiting the indemnity provisions of the Agreement, Consultant shall, at its expense, procure and maintain infull force and effect for the duration of the Agreement the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Consultant agrees to amend, supplement or endorse the policies to do so.
3.15.2 Additional Insured. The City of Ontario, its officials, officers, employees, agents, and volunteers shall be named as additional insureds on Consultant’s and its subconsultants’ policies of commercial general liability and automobile liability insurance using the endorsements and forms specified herein or exact equivalents.
3.15.3 Commercial General Liability
(a) The Consultant shall take out and maintain, during the performance of all work under this Agreement, in amounts not less than specified herein, Commercial General Liability Insurance, in a form and with insurance companies acceptable to the City. (b) Coverage for Commercial General Liability insurance shall be at least as broad as the following: Insurance Services Office Commercial General Liability coverage (Occurrence Form CG 00 01) or exact equivalent. Commercial General Liability Insurance must include coverage for the following:
(i) Bodily Injury and Property Damage
(ii) Personal Injury/Advertising Injury
(iii) Premises/Operations Liability
(iv) Products/Completed Operations Liability
(v) Aggregate Limits that Apply per Project
(vi) Explosion, Collapse and Underground (UCX) exclusion deleted
(vii) Contractual Liability with respect to this Contract (viii) Broad Form Property Damage
(ix) Independent Consultants Coverage
(c) The policy shall contain no endorsements or provisions limiting coverage for (1) contractual liability; (2) cross liability exclusion for claims or suits by one insured against another; (3) products/completed operations liability; or (4) contain any other exclusion contrary to the Agreement.
565
BB&K (2023)
46700.00100\40935196.1
-15-
(d) The policy shall give City, the City Council and each member of the City Council, its officers, employees, agents and City designated volunteers additional insured status using ISO endorsement forms CG 20 10 10 01 and 20 37 10 01, or endorsements providing the exact same coverage.
(e) The general liability program may utilize either deductibles or provide coverage excess of a self-insured retention, subject to written approval by the City, and provided that such deductibles shall not apply to the City as an additional insured.
3.15.4 Automobile Liability
(a) At all times during the performance of the work under this Agreement, the Consultant shall maintain Automobile Liability Insurance for bodily injury and property damage including coverage for owned, non-owned and hired vehicles, in a form and with insurance companies acceptable to the City.
(b) Coverage for automobile liability insurance shall be at least as broad as Insurance Services Office Form Number CA 00 01 covering automobile liability (Coverage Symbol 1, any auto).
(c) The policy shall give City, the City Council and each member of the City Council, its officers, employees, agents and City designated volunteers additional insured status.
(d) Subject to written approval by the City, the automobile liability program may utilize deductibles, provided that such deductibles shall not apply to the City as an additional insured, but not a self-insured retention.
3.15.5 Workers’ Compensation/Employer’s Liability
(a) Consultant certifies that he/she is aware of the provisions of Section 3700 of the California Labor Code which requires every employer to be insured against liability for workers’ compensation or to undertake self-insurance in accordance with the provisions of that code, and he/she will comply with such provisions before commencing work under this Agreement.
(b) To the extent Consultant has employees at any time during the term of this Agreement, at all times during the performance of the work under this Agreement, the Consultant shall maintain full compensation insurance for all persons employed directly by him/her to carry out the work contemplated under this Agreement, all in accordance with the “Workers’ Compensation and Insurance Act,” Division IV of the Labor Code of the State of California and any acts amendatory thereof, and Employer’s Liability Coverage in amounts indicated herein. Consultant shall require all subconsultants to obtain and maintain, for the period required by this Agreement, workers’ compensation coverage of the same type and limits as specified in this Section.
3.15.6 Professional Liability (Errors and Omissions)
(a) At all times during the performance of the work under this Agreement the Consultant shall maintain professional liability or Errors and Omissions insurance appropriate to its profession, in a form and with insurance companies acceptable to the City and 566
BB&K (2023)
46700.00100\40935196.1
-16-
in an amount indicated herein. This insurance shall be written on a policy form coverage specifically designed to protect against acts, errors or omissions of the Consultant. “Covered Professional Services” as designated in the policy must specifically include work performed under this Agreement. The policy must “pay on behalf of” the insured and must include a provision establishing the insurer's duty to defend.
3.15.7 Minimum Policy Limits Required
(a) The following insurance limits are required for the Agreement:
Coverage Combined Single Limit
Commercial General Liability $2,000,000 per occurrence/ $4,000,000 aggregate for bodily injury, personal
injury, and property damage
Automobile Liability $2,000,000 per occurrence for bodily injury and property damage
Employer’s Liability $1,000,000 per occurrence
Professional Liability $2,000,000 per claim and aggregate (errors and omissions)
(b) Defense costs shall be payable in addition to the limits. (c) Requirements of specific coverage or limits contained in this Section are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance. Any available coverage shall be provided to the parties required to be named as Additional Insured pursuant to this Agreement.
3.15.8 Evidence Required
(a) Prior to execution of the Agreement, the Consultant shall file with the City evidence of insurance from an insurer or insurers certifying to the coverage of all insurance required herein. Such evidence shall include original copies of the ISO CG 00 01 (or insurer’s equivalent) signed by the insurer’s representative and Certificate of Insurance (Acord Form 25-S or equivalent), together with required endorsements. All evidence of insurance shall be signed by a properly authorized officer, agent, or qualified representative of the insurer and shall certify the names of the insured, any additional insureds, where appropriate, the type and amount of the insurance, the location and operations to which the insurance applies, and the expiration date of such insurance.
3.15.9 Policy Provisions Required
(a) Consultant shall provide the City at least thirty (30) days prior written notice of cancellation of any policy required by this Agreement, except that the Consultantshall provide at least ten (10) days prior written notice of cancellation of any such policy due to nonpayment of premium. If any of the required coverage is cancelled or expires during the termof this Agreement, the Consultant shall deliver renewal certificate(s) including the General Liability Additional Insured Endorsement to the City at least ten (10) days prior to the effective date of cancellation or expiration.
567
BB&K (2023)
46700.00100\40935196.1
-17-
(b) The Commercial General Liability Policy and Automobile Policy shall each contain a provision stating that Consultant’s policy is primary insurance and that any insurance, deductible, or self-insurance maintained by the City, its officials, officers, employees, agents, or volunteers shall not contribute with this primary insurance. Policies shall contain or be endorsed to contain such provisions.
(c) The retroactive date (if any) of each policy is to be no later than the effective date of this Agreement. Consultant shall maintain such coverage continuously for a period of at least three years after the completion of the work under this Agreement. Consultant shall purchase a one (1) year extended reporting period A) if the retroactive date is advanced past the effective date of this Agreement; B) if the policy is cancelled or not renewed; or C) if thepolicy is replaced by another claims-made policy with a retroactive date subsequent to the effective date of this Agreement.
(d) All required insurance coverages, except for the professional liability coverage, shall contain or be endorsed to waiver of subrogation in favor of the City, its officials, officers, employees, agents, and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these specifications to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants.
(e) The limits set forth herein shall apply separately to each insured against whom claims are made or suits are brought, except with respect to the limits of liability.
Further the limits set forth herein shall not be construed to relieve the Consultant from liability in excess of such coverage, nor shall it limit the Consultant’s indemnification obligations to the City and shall not preclude the City from taking such other actions available to the City under other provisions of the Agreement or law.
3.15.10 Qualifying Insurers
(a) All policies required shall be issued by acceptable insurance companies, as determined by the City, which satisfy the following minimum requirements: Each such policy shall be from a company or companies with a current A.M. Best's rating of no less than A:VII and admitted to transact in the business of insurance in the State of California, or otherwise allowed to place insurance through surplus line brokers under applicable provisions of the California Insurance Code or any federal law.
3.15.11 Additional Insurance Provisions
(a) The foregoing requirements as to the types and limits of insurance coverage to be maintained by Consultant, and any approval of said insurance by the City, is not intended to and shall not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Consultant pursuant to this Agreement, including but not limited to, the provisions concerning indemnification.
(b) If at any time during the life of the Agreement, any policy of insurance required under this Agreement does not comply with these specifications or is canceled and not replaced, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Consultant or City will withhold 568
BB&K (2023)
46700.00100\40935196.1
-18-
amounts sufficient to pay premium from Consultant payments. In the alternative, City may cancel this Agreement.
(c) The City may require the Consultant to provide complete copies of all insurance policies in effect for the duration of the Project. (d) Neither the City nor the City Council, nor any member of the City Council, nor any of the officials, officers, employees, agents or volunteers shall be personally responsible for any liability arising under or by virtue of this Agreement.
3.15.12 Subconsultant Insurance Requirements
(a) Consultant shall not allow any subcontractors or subconsultants to commence work on any subcontract until they have provided evidence satisfactory to the City that they have secured all insurance required under this Section. Policies of commercial general liability insurance provided by such subcontractors or subconsultants shall be endorsed to name the City as an additional insured using ISO form CG 20 38 04 13 or an endorsement providing the exact same coverage. If requested by Consultant, City may approve different scopes or minimum limits of insurance for particular subcontractors or subconsultants.
3.16 Records.
Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to thisAgreement.
Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of five (5) years from the date of final payment under this Agreement.
3.17 Standardized Manufactured Items.
Consultant shall cooperate and consult with City in the use and selection of manufactured items on the Project, including but not limited to, paint, hardware, plumbing, mechanical and electrical equipment, fixtures, roofing materials and floor coverings. All such manufactured items shall be standardized to City’s criteria to the extent such criteria do not interfere with building design.
3.18 Limitation of Agreement.
This Agreement is limited to and includes only the work included in the Project described herein. Any additional or subsequent construction at the site of the Project, or at any other City site, will be covered by, and be the subject of, a separate Agreement for architectural services between City and the Consultant chosen therefor by City.
3.19 Mediation.
Disputes arising from this Agreement may be submitted to mediation if mutually agreeable to the Parties hereto. The type and process of mediation to be utilized shall be subject to the mutual agreement of the Parties.
569
BB&K (2023)
46700.00100\40935196.1
-19-
3.20 Successors and Assigns.
This Agreement shall be binding upon and shall inure to the benefit of the successors in interest, executors, administrators and assigns of each Party to this Agreement. However, Consultant shall not assign or transfer by operation of law or otherwise any or all of its rights, burdens, duties or obligations without the prior written consent of City. Any attempted assignment without such consent shall be invalid and void.
3.21 Asbestos Certification.
Consultant shall certify to City, in writing and under penalty of perjury, that to the best of its knowledge, information and belief no asbestos-containing material or other material deemed to be hazardous by the state or federal government was specified as a building material in any construction document that the Consultant prepares for the Project. Consultant shall require all consultants who prepare any other documents for the Project to submit the same written certification. Consultant shall also assist the City in ensuring that contractors provide City with certification, in writing and under penalty of perjury, that to the best of their knowledge, information and belief no material furnished, installed or incorporated into the Project contains asbestos or any other material deemed to be hazardous by the state or federal government. These certifications shall be part of the final Project submittal. Consultant shall include statements in its specifications that materials containing asbestos or any other material deemed to be hazardous by the state or federal government are not to be included.
3.22 No Third Party Rights.
This Agreement shall not create any rights in, or inure to the benefits of, any third party except as expressly provided herein.
3.23 Governing Law.
This Agreement shall be construed in accordance with, and governed by, the laws of the State of California. Venue shall be in San Bernardino County.
3.24 Exhibits and Recitals.
All exhibits and recitals contained herein and attached hereto are material parts of this Agreement and are incorporated as if fully set forth.
3.25 Severability.
Should any provision in the Agreement be held by a court of competent jurisdiction to be invalid, void, or unenforceable, the remaining provisions shall continue in full force and effect.
3.26 Non-Waiver.
None of the provisions of this Agreement shall be considered waived by either Party, unless such waiver is specifically specified in writing. 570
BB&K (2023)
46700.00100\40935196.1
-20-
3.27 Safety.
Consultant shall execute and maintain its work so as to avoid injury or damage to any person or property. In carrying out its Services, the Consultant shall at all times be in compliance with all applicable local, state and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of its employees, consultant and subcontractors appropriate to the nature of the work and the conditions under which the work is to be performed.
3.28 Harassment Policy.
Consultant shall provide a copy of the City's Harassment Policy to each of its employees assigned to perform the tasks under this Agreement. Consultant shall submit to the City's Personnel Manager a statement signed by each of its employees who are assigned to perform the Services under this Agreement certifying receipt of City's Harassment Policy and certifying that they have read the Harassment Policy. A finding by the City that any of Consultant's employees has harassed a City employee shall be grounds for appropriate discipline, up to and including such employee's removal from performance of this Agreement at City's request.
3.29 Delivery of Notices.
All notices permitted or required under this Agreement shall be given to the respective Parties at the following address, or at such other address as the respective Parties may provide in writing for this purpose:
CITY:
City of Ontario
303 East “B” Street
Ontario, CA 91764
Attn: Adrian Escamilla, Design and Construction
CONSULTANT:
RDC – S111, Inc.
245 E. 3rd St.
Long Beach, CA 90802
Attn: Mitra Esfandiari, Partner
Such notice shall be deemed made when personally delivered or when mailed, forty-eight (48) hours after deposit in the U.S. Mail, first class postage prepaid and addressed to the Party at its applicable address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.
3.30 Time of Essence.
Time is of the essence for each and every provision of this Agreement.
3.31 City’s Right to Employ Other Consultants.
City reserves right to employ other consultants, including designers, in connection with this Project or other projects.
3.32 Prohibited Interests.
3.32.1 Solicitation. Consultant maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for 571
BB&K (2023)
46700.00100\40935196.1
-21-
Consultant, to solicit or secure this Agreement. Further, Consultant warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability.
3.32.2 Conflict of Interest. For the term of this Agreement, no director, official, officer or employee of City, during the term of his or her service with City, shall have any direct interest in this Agreement, or obtain any present or anticipated material benefit arising therefrom.
3.33 Equal Opportunity Employment.
Consultant represents that it is an equal opportunity employer and that it shall not discriminate against any employee or applicant for employment because of race, religion, color, national origin, ancestry, sex, age or any other classification protected by federal or state law.
Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination. Consultant shall also comply with all relevant provisions of City’s minority business enterprise program, affirmative action plan or other related programs or guidelines currently in effect or hereinafter enacted.
3.34 Labor Certification.
By its signature hereunder, Consultant certifies that it is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker’s Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services.
3.35 Subcontracting.
As specified in this Agreement, Consultant shall not subcontract any portion of the Services required by this Agreement, except as expressly stated herein, without prior written approval of City. Subcontracts, if any, shall contain a provision making them subject to each and every provision of this Agreement.
3.36 Supplemental Conditions.
Any supplemental conditions shall be attached as an exhibit to this Agreement, and that exhibit shall be incorporated herein by reference.
3.37 Entire Agreement.
This Agreement, with its exhibits, contains the entire agreement of the Parties hereto, and supersedes any and all other prior or contemporaneous negotiations, understandings and oral or written agreements between the Parties hereto. Each Party acknowledges that no representations, inducements, promises or agreements have been made by any person which are not incorporated herein, and that any other agreements shall be void. Furthermore, any 572
BB&K (2023)
46700.00100\40935196.1
-22-
modification of this Agreement shall only be effective if in writing signed by all Parties hereto.
SIGNATURES ON FOLLOWING PAGE
573
BB&K (2023) -23-
46700.00100\40935196.1
SIGNATURE PAGE FOR DESIGN SERVICES AGREEMENT
BETWEEN THE CITY OF ONTARIO
AND RDC – S111, Inc.
IN WITNESS WHEREOF, the Parties have executed this Agreement as of the date first written above.
CITY OF ONTARIO RDC – S111, Inc.
By:
Its:
Printed Name:
By:
Its:
Printed Name:
[If Corporation, TWO SIGNATURES,
President OR Vice President AND Secretary
OR Treasurer REQUIRED]
Approved By:
Scott Ochoa
City Manager
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:
City Clerk
City Clerk
574
BB&K (2023)
46700.00100\40935196.1
Exhibit A-1
EXHIBIT “A”
SCOPE OF SERVICES
1. GENERAL REQUIREMENTS.
1.1 Basic Services. Consultant agrees to perform all the necessary professional architectural, engineering (e.g. mechanical, electrical, plumbing, structural, site engineering, and any other necessary engineering services mutually agreeable to the Parties) and construction administration services for the Project in a timely and professional manner, consistent with the standards of the profession, including those provided for herein.
1.2 Exclusions from Basic Services. The following services shall be excluded from the basic services listed above: Exclusions will be determined on a project-by-project basis.
1.3 Additional Services. Consultant shall perform the following Additional Services for the Project: Additional Services will be determined on a project by project.
1.4 Communication with City. Consultant shall participate in consultations and conferences with authorized representatives of City and/or other local, regional, or state agencies concerned with the Project, which may be necessary for the completion of the Project or the development of the drawings, specifications and documents in accordance with the applicable standards and requirements of law and the City. Such consultations and conferences shall continue throughout the planning and construction of the Project and the contractor’s warranty period. Consultant shall take direction only from the City’s Representative, or any other representative specifically designated by the City for this Project, including any construction manager hired by the City.
1.5 Coordination and Cooperation with Construction Manager. The City may hire a construction manager to administer and coordinate all or any part of the Project on its behalf. If the City does so, it shall provide a copy of its agreement with the construction manager so that the Consultant will be fully aware of the duties and responsibilities of the construction manager.
The Consultant shall cooperate with the construction manager and respond to any requests or directives authorized by the City to be made or given by the construction manager. The Consultant shall request clarification from the City in writing if the Consultant should have any questions regarding the authority of the construction manager.
2. INITIAL PLANNING PHASE.
During the initial planning phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
2.1 Project Feasibility. Provide advice and assistance to City in determining the feasibility of the Project, analysis of the type and quality of materials and construction to be selected, the site location, and other initial planning matters.
2.2 Meeting Budget and Project Goals. Consultant shall notify City in writing of potential complications, cost overruns, unusual conditions, and general needs that potentially impact the Project budget and time line, including the City’s Preliminary Construction Budget.
Consultant shall use its best judgment in determining the balance between the size, type and 575
BB&K (2023)
46700.00100\40935196.1
Exhibit A-1
quality of construction to achieve a satisfactory solution within the Project’s budget and construction allowance. It shall be the duty of the Consultant to design the Project within budget.
As discussed herein, including in Section 7.3, if the lowest responsive and responsible bid for the Project exceeds the budget by the stated amount, Consultant may be required to make the necessary changes in the drawing and specifications, at its sole cost and expense, to bring the bids within the required budget.
2.3 Permits, Approvals and Authorizations. As indicated in Section 3.5.4 of the Agreement, Consultant shall assist City in securing easements, encroachment permits, rights of way, dedications, infrastructures and road improvements, as well as coordinating with utilities and adjacent property owners.
3. SCHEMATIC PLAN PHASE.
During the schematic plan phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
3.1 Funding Documents. Consultant shall provide a site plan and all other Projectrelated information necessary and required for an application by City to any federal, state, regional, or local agencies for funds to finance the construction Project.
3.2 Schematic Plans. In cooperation with City, Consultant shall prepare preliminary plans and studies, schematic drawings, site utilization plans, and phasing plans showing the scale and relationship of the components of the Project, the plot plan development at the site, and the proposed architectural concept of the buildings (“Schematic Plans”). Consultant shall incorporate the functional requirements of City into the Schematic Plans. The Schematic Plans shall meet all laws, rules and regulations of the State of California. The Schematic Plans shall show all rooms incorporated in each building of the Project in single-line drawings, and shall include all revisions required by City or by any federal, state, regional or local agency having jurisdiction over the Project. All architectural drawings for the Project shall be in a form suitable for reproduction.
3.3 Preliminary Project Budget. Consultant shall use the City’s Preliminary Construction Budget and its own expertise and experience with the Project to establish a preliminary project budget or allowance in a format required by City (“Consultant’s Preliminary Project Budget”). The purpose of the Consultant’s Preliminary Project Budget is to show the probable Project cost in relation to City’s Preliminary Construction Budget and the construction standards of any applicable funding agency. If Consultant perceives site considerations which render the Project expensive or cost prohibitive, Consultant shall disclose such conditions in writing to City immediately. As discussed herein, including in Section 7.3, if the lowest responsive and responsible bid for the Project exceeds the budget by more than the stated amount, Consultant may be required to make the necessary changes in the drawings and specifications, at its sole cost and expense, to bring the bids within the required budget Consultant shall provide a preliminary written time schedule for the performance of all construction work on the Project.
3.4 Copies of Schematic Plans and Other Documents. Consultant, at its own expense, shall provide a complete set of the Schematic Plans described herein for City’s review and approval. Additionally, at City’s expense, Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any additional copies required by City shall be provided at actual cost to City. 576
BB&K (2023)
46700.00100\40935196.1
Exhibit A-1
4. DESIGN DEVELOPMENT PHASE.
During the design development phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
4.1 Design Development Documents. Once City provides Consultant with specific written approval of the Schematic Plans described herein, Consultant shall prepare design development documents consisting of: (1) site and floor plans; (2) elevations; and (3) any other drawings and documents sufficient to fix and describe the types and makeup of materials, as well as the size and character of the Project’s structural, mechanical and electrical systems, and to outline the Project specifications (“Design Development Documents”). The Design Development Documents shall be prepared in sufficient form to present to the City Council for approval.
4.2 Copies of Design Development and Other Documents. Consultant, at its own expense, shall provide a complete set of the Design Development Documents described herein for City’s review and approval. Additionally, at City’s expense, Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any additional copies required by City shall be provided at actual cost to City.
4.3 Updated Project Budget. Consultant shall use its Preliminary Project Budget and expertise and experience with the Project to establish an updated estimate of probable construction costs, containing detail consistent with the Design Development Documents as set forth herein and containing a breakdown based on types of materials and specifications identified herein (“Consultant’s Updated Project Budget”).
4.4 Timetable. Consultant shall provide a written timetable for full and adequate completion of the Project to City.
4.5 Application for Approvals. Consultant shall assist City in applying for and obtaining required approvals from all federal, state, regional or local agencies concerned with the Project. Consultant shall furnish and process all architectural and engineering information required to prepare and process applications to applicable utilities in order to secure priorities and materials, to aid in the construction of the Project and to obtain final Project approval and acceptance by any of the above agencies as may be required.
4.6 Color and Other Aesthetic Issues. Consultant shall provide, for City’s review and approval, a preliminary schedule of all color materials and selections of textures, finishes andother matters involving an aesthetic decision about the Project.
5. FINAL WORKING DRAWINGS AND SPECIFICATIONS.
During the final working drawings and specifications phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
5.1 Final Working Drawings and Specifications. Once City provides Consultant with specific written approval of the Design Development Documents described herein, Consultant shall prepare such complete working drawings and specifications as are necessary for developing complete bids and for properly executing the Project work in an efficient and thorough manner (“Final Working Drawings and Specifications”). Such Final Working Drawings and Specifications shall be developed from the Schematic Plans and Design Development Documents approved by City. The Final Working Drawings and Specifications shall set forth in 577
BB&K (2023)
46700.00100\40935196.1
Exhibit A-1
detail all of the following: (1) the Project construction work to be done; (2) the materials, workmanship, finishes, and equipment required for the architectural, structural, mechanical, and electrical systems; and (3) the utility service connection equipment and site work. As indicated in Section 3.9.2 of the Agreement, City may be requested to supply Consultant with the necessary information to determine the proper location of all improvements on and off site, including record drawings (“as-built drawings”) in City’s possession. Consultant will make a good-faith effort to verify the accuracy of such information by means of a thorough interior and exterior visual survey of site conditions. City shall also make a good-faith effort to verify the accuracy of the as-built drawings and provide any supplemental information to Consultant which may not be shown on the as-built drawings.
5.2 Form. The Final Working Drawings and Specifications must be in such form as will enable Consultant and City to secure the required permits and approvals from all federal, state, regional or local agencies concerned with the Project. In addition, the Final Working Drawings and Specifications must be in such form as will enable City to obtain, by competitive bidding, a responsible and responsive bid within the applicable budgetary limitations and cost standards.
The Final Working Drawings and Specifications shall be clear and legible so that uniform copies may be on standard architectural size paper, properly indexed and numbered, andshall be capable of being clearly copied and assembled in a professional manner by Consultant.
5.3 Approval and Revisions. City shall review, study, and check the Final Working Drawings and Specifications presented to it by Consultant, and request any necessary revisions or obtain any necessary approvals by the City Council, subject to the approval of all federal, state, regional or local agencies concerned with the Project. Consultant shall make all City-requested changes, additions, deletions, and corrections in the Final Working Drawings and Specifications at no additional cost, so long as they are not in conflict with the requirements of public agencies having jurisdiction or prior approval, or inconsistent with earlier City direction or Consultant’s professional judgment. Consultant shall bring any such conflicts and/or inconsistencies to the attention of City. The Parties agree that Consultant, and not the City, possesses the requisite expertise to determine the constructability of the Final Working Drawings and Specifications.
However, the City reserves the right to conduct one or more constructability review processes with the Final Working Drawings and Specifications, and to hire an independent architect or other consultant to perform such reviews. Any such independent constructability review shall be at City’s expense. Consultant shall make all City-requested changes, additions, deletions, and corrections in the Final Working Drawings and Specifications which may result from any constructability review, at no additional cost to the City, so long as they are not in conflict with the requirements of public agencies having jurisdiction or prior approval, or inconsistent with earlier City direction or Consultant’s professional judgment. If such changes, additions, deletions or corrections are inconsistent with prior City direction, Consultant shall make such alterations and be compensated therefore pursuant to the Additional Services provision of this Agreement.
5.4 Costs of Construction. It is understood by Consultant that should the Final Working Drawings and Specifications be ordered by City, City shall specify the sum of money set aside to cover the total cost of construction of the work, exclusive of Consultant’s fees. Should it become evident that the total construction cost will exceed the specified sum, Consultant shall at once present a statement in writing to the City’s Representative setting forth this fact and giving a full statement of the cost estimates on which the conclusion is based.
5.5 Copies of Final Working Drawings and Specifications and Other Documents.
Consultant, at its own expense, shall provide a complete set of the Final Working Drawings and Specifications described herein for City’s review and approval. Additionally, at City’s expense, 578
BB&K (2023)
46700.00100\40935196.1
Exhibit A-1
Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any additional copies required by City shall be provided at actual cost to City.
6. CONSTRUCTION CONTRACT DOCUMENTS.
During the construction contract documents phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
6.1 Bid and Contract Documents. If so required by City, Consultant shall assist City in the completion of all bid and construction documents, including but not limited to, the Notice Inviting Bids, Instructions to Bidders, Contract Bid Forms (including Alternate Bids as requested by City), `Contract, General Conditions, Supplementary General Conditions, Special Conditions, DVBE and other applicable affirmative action documents, Performance Bond, Payment Bond, Escrow Agreement for Security Deposits, and any other certifications and documents required by federal, state and local laws, rules and regulations which may be reasonably required in order to obtain bids responsive to the specifications and drawings. All such documents shall be subject to the approval of City and City’s legal counsel.
6.2 Final Estimate. At the time of delivery of these bid and construction documents, which shall include the Final Working Drawings and Specifications (collectively referred to herein as the “Construction Documents”), Consultant shall provide City with its final estimate of probable construction cost (“Consultant’s Final Estimate”). As discussed herein, including in Section 7.3, it shall be the Consultant’s duty to design the Project within budget.
7. BID PHASE.
During the bid phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
7.1 Reproducible Construction Documents. Once City provides Consultant with specific written approval of the Construction Documents and Consultant’s Final Estimate, Consultant shall provide to City one set of reproducible Construction Documents.
7.2 Distribution of Contract Documents and Review of Bids. Consultant shall assist City in distributing the Construction Documents to bidders and conducting the opening and review of bids for the Project.
7.3 Over Budget. If the apparent lowest responsive and responsible bid on the Project exceeds the Consultant’s Final Estimate by more than five percent (5%), City may request Consultant to amend, at Consultant’s sole cost and expense, the Final Drawings and Specifications in order to rebid the Project and receive a lowest responsive and responsible bid equal to or less than the Consultant’s Final Estimate. All revisions necessary to bring the lowest responsible and responsive bid within the Consultant’s Final Estimate, including any omissions, deferrals or alternates, shall be made in consultation with, and subject to the approval of, the City.
8. CONSTRUCTION PHASE.
During the construction phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
579
BB&K (2023)
46700.00100\40935196.1
Exhibit A-1
8.1 Observation. The Project Consultant shall observe work executed from the Final Working Drawings and Specifications in person, provided that City may, in its discretion, consent to such observation by another competent representative of Consultant.
8.2 General Administration. Consultant shall provide general administration of the Construction Documents and the work performed by the contractors.
8.3 Pre-Construction Meeting. Consultant shall conduct one or more preconstruction meetings, as the City determines is needed for the Project, with all interested Parties.
8.4 Site Visits of Contractor’s Work. Consultant shall conduct site visits to observe each contractors’ work for general conformance with the Construction Documents and with any approved construction schedules or milestones. Such site visits shall be conducted as often as are necessary and appropriate to the stage of construction, according to the City’s sole discretion, but in no event less than weekly.
8.5 Site Visits of Inspector’s Work. Consultant shall conduct site visits to communicate and observe the activities of the City inspectors. Such site visits shall be conducted as often as is mutually acceptable to Consultant and City. Consultant shall direct the City inspectors and the Project contractors to coordinate the preparation of record drawings indicating dimensions and location of all “as-built” conditions, including but not limited to, underground utility lines.
8.6 Coordination of Subconsultants. Consultant shall cause all architects, engineers and other consultants, as may be hired by Consultant or City, to observe the work completed under their disciplines as required, and approve and review all test results for general conformance with the Construction Documents.
8.7 Reports. Consultant shall make regular reports as may be required by applicable federal, state or local laws, rules or regulations, as well as the federal, state, regional or local agencies concerned with the Project.
8.8 Construction Meetings; Minutes. Consultant shall attend all construction meetings and provide written reports/minutes to the City after each construction meeting in order to keep City informed of the progress of the work. Such meetings shall occur at a frequency necessary for the progress of the Project work, according to the City’s sole discretion, but no less than weekly.
8.9 Written Reports. Consultant shall make written reports to City as necessary to inform City of problems arising during construction, changes contemplated as a result of each such problems, and progress of the Project work.
8.10 Written Records. Consultant shall keep accurate written records of the progress and quality of the Project work and the time schedules, and shall advise the contractors and City of any deviations from the time schedule which could delay timely completion of the Project.
8.11 Material and Test Reports. Consultant shall check and process, in a timely manner, all required material and test reports for the Project work. In addition, Consultant shall provide notice of any deficiencies in material or work reflected in such reports, as well as its recommendation for correction of such deficiencies, to the contractors and City. 580
BB&K (2023)
46700.00100\40935196.1
Exhibit A-1
8.12 Review and Response to Submissions. Consultant shall review and respond, in a timely manner, to all schedules, submittals, shop drawings, samples, information requests, change requests, and other submissions of the contractor and subcontractors for compliance with, or alterations and additions to, the Construction Documents. Consultant’s review and response shall be done in such a manner so as to ensure the timely and uninterrupted progress of the Project work.
8.13 Rejection of Work. Consultant shall promptly reject, as discussed with City, work or materials which do not conform to the Construction Documents. Consultant shall immediately notify the City and contractor(s) of such rejections. Consultant shall also have the authority to recommend to the City that additional inspection or testing of the work be performed, whether or not such work is fabricated, installed or completed.
8.14 Substitutions. Consultant shall consult with City, in a timely manner, with regard to substitution of materials, equipment and laboratory reports thereof, prior to the City’s final written approval of such substitutions. Consultant’s consultation shall be done in such a manner so as to ensure the timely and uninterrupted progress of the Project work.
8.15 Revised Documents and Drawings. Consultant shall prepare, at no additional expense to City, all documents and/or drawings made necessary by errors and omissions in the originally approved Construction Documents.
8.16 Change Requests and Material Changes. Consultant shall evaluate and advise City, in a timely manner and in writing, of any change requests and material change(s) which may be requested or necessary in the Project plans and specifications. Consultant shall provide the City with its opinion as to whether such change requests should be approved, denied or revised.
If the City has not hired a construction manager or other person to do so, the Consultant shall prepare and execute all change orders and submit them to the City for authorization. If the City has designated a construction manager or other person to prepare all change orders, the Consultant shall review all change orders prepared by such person, execute them and deliver them to the City for authorization if they meet with the Consultant’s approval, or submit them to the City with recommendations for revision or denial if necessary. Consultant shall not order contractors to make any changes affecting the contract price without approval by City of such a written change order, pursuant to the terms of the Construction Documents. Consultant may order, on its own responsibility and pending City Council approval, changes necessary to meet construction emergencies, if written approval of City’s Representative is first secured.
8.17 Applications for Payment. Consultant shall examine, verify and approve contractor’s applications for payment, and shall issue certificates for payment in amounts approved by the City’s inspector.
8.18 Final Color and Product Selection. Consultant shall coordinate final color and product selection with City’s original design concept.
8.19 Substantial Completion. Consultant shall determine the date of substantial completion, in consultation with the City.
8.20 Punch List. After determining that the Project is substantially complete, Consultant shall participate in the inspection of the Project and shall review all remaining deficiencies and minor items needed to be corrected or completed on the Project, including those identified on the punch list prepared by the contractor (“Punch List Items”). Consultant shall notify 581
BB&K (2023)
46700.00100\40935196.1
Exhibit A-1
contractor in writing that all Punch List Items must be corrected prior to final acceptance of the Project and final payment. Consultant shall also notify City of all Punch List Items.
8.21 Warranties. Consultant shall review materials assembled by the contractor and subcontractors with regard to all written warranties, guarantees, owners’ manuals, instruction books, diagrams, record “as built” drawings, and any other materials required from the contractors and subcontractors pursuant to the Construction Documents. Consultant shall coordinate and provide these materials to the City.
8.22 Certificate of Completion. Consultant shall participate in any further inspections of the Project necessary to issue Consultant’s Certificate of Completion and final certificate for payment.
8.23 Documents for Project Close-Out. Consultant shall cause all other architects, engineers and other consultants, as may be hired by Consultant, to file any and all required documentation with the City or other governmental authorities necessary to close out the Project.
Consultant shall assist the City in obtaining such documentation from all other architects, engineers, or other consultants.
9. AS-BUILT DRAWINGS.
During the as-built drawings phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
9.1 As-Built Drawings and Specifications. Not later than thirty (30) days after substantial completion of the Project, before receipt of final payment, Consultant shall review and forward the Final Working Drawings and Specifications, indicating on them all changes made by change orders or otherwise pursuant to the Construction Documents, as well as all information called for on the specifications, thus producing an “as-built” set of Final Working Drawings and Specifications (“As-Built Drawings and Specifications”). The As-Built Drawings and Specifications shall show, among other things, the location of all concealed pipe, buried conduit runs and other similar elements within the completed Project. Consultant shall personally review and certify that the As-Built Drawings and Specifications are a correct representation of the information supplied to Consultant by any inspectors and the contractor, and shall obtain certifications from any inspectors and the contractor that the drawings are correct.
9.2 Approval. Once City provides Consultant with specific written approval of the AsBuilt Drawings and Specifications, Consultant shall forward to City the complete set of original AsBuilt Drawings and Specifications or a complete set of reproducible duplicate As-Built Drawings and Specifications. The tracing shall be of such quality that clear and legible prints maybe made without appreciable and objectionable loss of detail.
9.3 Documents for Final Payment. Prior to the receipt of Consultant’s final payment, Consultant shall forward to City all of the following: (1) one clear and legible set of reproductions of the computations; (2) the original copy of the specifications; (3) the As-Built Drawings and Specifications as required herein; and (4) Consultant’s Certificate of Completion.
10. WARRANTY PERIOD.
During the warranty period phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
582
BB&K (2023)
46700.00100\40935196.1
Exhibit A-1
10.1 Advice. Consultant shall provide advice to City on apparent deficiencies in the Project during any applicable warranty periods for the Project. 583
BB&K (2023)
46700.00100\40935196.1
Exhibit B-1
EXHIBIT “B”
FEE AND PHASING/FUNDING SCHEDULES
1. FEE SCHEDULE.
Consultant will invoice City on a monthly cycle based on the following fee schedule.
Consultant will include with each invoice a detailed progress report that indicates the amount of budget spent on each phase and the total amount spent against the Total Compensation.
Consultant will inform City regarding any out-of-scope work being performed by Consultant for which Consultant intends to seek compensation from City.
2. PHASING/FUNDING SCHEDULE.
Progress payments towards Total Compensation shall never exceed the following percentages of Total Compensation as of the phase indicated:
584
(BB&K 2020)
46700.00100\33865500.1
585
BB&K (2023)
46700.00100\40935196.1
-1-
CITY OF ONTARIO
DESIGN SERVICES AGREEMENT
1. PARTIES AND DATE.
This Agreement is made and entered into as of , by and between the City of Ontario, a municipal corporation organized and operating under the laws of the State of California with its principal place of business at 303 East “B” Street, Ontario, California 91764- 4196, County of San Bernardino, State of California (“City”), and Westgroup Designs, Inc. a corporation with its principal place of business at 19900 MacArthur Blvd., Suite 1000, Irvine, CA 92612 (hereinafter referred to as “Consultant”). City and Consultant are sometimes individually referredto herein as “Party” and collectively as “Parties.”
2. RECITALS.
2.1 City. City is a municipal corporation organized under the laws of the State of California, with power to contract for services necessary to achieve its purpose.
2.2 Consultant. Consultant desires to perform and assume responsibility for the provision of certain professional architectural design services requiredby the City on the terms and conditions set forth in this Agreement. Consultant warrants that it isfully licensed, qualified, and willing to perform the services required by this Agreement; provided, however, that if Consultant is a corporation or other organization, the Project Consultant designated pursuant to Section 3.2, and not the Consultant itself, shall be fully licensed to practiceas an architect in the State of California.
2.3 Project. City desires to engage Consultant to render such services for the On-Call Retail Architect Design Services ("Project") as set forth in this Agreement.
3. TERMS
3.1 Employment of Consultant.
3.1.1 Scope of Services. Consultant promises and agrees to furnish to City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the professional architectural and related services necessary for the full and adequate completion of the Project consistent with the provisions of this Agreement 586
BB&K (2023)
46700.00100\40935196.1
-2-
(hereinafter referred to as “Services”). The Services are more particularly described throughout this Agreement, including Exhibit “A” attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordancewith, this Agreement, any exhibits attached hereto and incorporated herein by reference, and allapplicable local, state and federal laws, rules and regulations. All Services performed by Consultant shall be subject to the sole and discretionary approval of the City, which approval shallnot be unreasonably withheld.
3.1.2 Term. The term of this Agreement shall be from July 16, 2024, to July 16, 2027, The City shall have the unilateral option, at its sole discretion, to renew this Agreement automatically for no more than two additional one-year terms unless earlier terminated as provided herein. Consultant shall complete the Services within the term of agreement and shall meet any other established scheduled and deadlines.
3.2 Project Consultant; Key Personnel.
3.2.1 Retail Architect. Consultant shall name a specific individual to act as Project Consultant, subject to the approval of City. Consultanthereby designates PariSima Hassani to act as the Retail Architect for the Project. The Architect shall: (1) maintain oversight of the Services; (2) have full authority to represent and act on behalf of the Consultant for all purposes under this Agreement; (3) supervise and direct the Services using his or her best skill and attention; (4) be responsible for the means, methods, techniques, sequences and procedures used for the Services; (5) adequately coordinate all portions of the Services; and (6) act as principal contact with y and all contractors, consultants, engineers and inspectors on the Project. Any change in the Retail Architect shall be subject to the City’s prior written approval, which approval shall not be unreasonably withheld. The new Retail Architect shall be of at least equal competence as the prior Retail Architect. In the event that City and Consultant cannotagree as to the substitution of a new Retail Architect. City shall be entitled to terminate this Agreement for cause.
3.2.2 Key Personnel. In addition to the Retail Architect, Consultant has represented to the City that certain additional key personnel, engineers and consultants will perform the Services under this Agreement. Should one or more of such personnel, engineers or consultants become unavailable, Consultant may substitute others of atleast equal competence upon written approval of the City. In the event that City and Consultant cannot agree as to the substitution of key personnel, engineers or consultants, City shall be entitled to terminate this Agreement for cause. The key additional personnel, engineers and consultants for performance of this Agreement are as follows: PariSima Hassani, CEO
3.3 Hiring of Consultants and Personnel.
3.3.1 Right to Hire or Employ. Consultant shall have the option, unless City objects in writing after notice, to employ at its expense architects, engineers, experts or other consultants qualified and licensed to render services in connection with the planning and/or administration of the Project, and to delegate to them such duties as Consultant may delegate without relieving Consultant from administrative or other responsibility under this Agreement.
Consultant shall be responsible for the coordination and cooperation of Consultant’s architects, engineers, experts or other consultants. All consultants, including changes in consultants, shall be subject to approval by City in its sole and reasonable discretion. Consultant shall notify City of the identity of all consultants at least fourteen (14) days prior to their commencement of work to allow City to review their qualifications and approve to their participation on the Project in its 587
BB&K (2023)
46700.00100\40935196.1
-3-
sole and reasonable discretion.
3.3.2 Qualification and License. All architects, engineers, experts and other consultants retained by Consultant in performance of this Agreement shall be qualified to perform the Services assigned to them, and shall be licensed to practice in their respective professions, where required by law.
3.3.3 Standards and Insurance. All architects, engineers, experts and other consultants hired by Consultant shall be required to meet all of the same standards and insurance requirements set forth in this Agreement, unless other standards or requirements are approved by the City in writing. Unless changes are approved in writing by the City, Consultant’s agreements with its consultants shall contain a provision making them subject to all provisions stipulated in this Agreement.
3.3.4 Assignments or Staff Changes. Consultant shall promptly obtain written City approval of any assignment, reassignment or replacement of such architects, engineers, experts and consultants, or of other staff changes of key personnel working on the Project. As provided in the Agreement, any changes in Consultant’s consultants and key personnel shall be subject to approval by City.
3.3.5 Draftsman and Clerical Support. Draftsmen and clerical personnel shall be retained by Consultant at Consultant’s sole expense.
3.4 Standard of Care.
3.4.1 Standard of Care. Consultant shall perform all Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals qualified to perform the Services in the same discipline in the State of California, and shall be responsible to City for damages sustained by the City and delays to the Project as specified in the indemnification provision of this Agreement. Without limiting the foregoing, Consultant shall be fully responsible to the City for any increased costs incurred by the City as a result of any such delays in the design or construction of the Project. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services. Consultant warrants and represents that all of its employees, architects, engineers, experts and other consultants shall have sufficient skill and experience to perform the Services assigned to them. Finally, Consultant represents that it, its employees, architects, engineers, experts and other consultants have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services assigned to or rendered by them and that such licenses and approvals shall be maintained throughout the term of this Agreement. As provided for in the indemnification provisions of this Agreement, Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant’s failure to comply with the standard of care provided for herein.
3.4.2 Performance of Employees. Any employee or consultant who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee or consultant who fails or refuses to perform the Services in a manner acceptable to the City, shall 588
BB&K (2023)
46700.00100\40935196.1
-4-
be promptly removed from the Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.
3.5 Laws and Regulations.
3.5.1 Knowledge and Compliance. Consultant shall keep itself fully informed of and in compliance with all applicable local, state and federal laws, rules and regulations in any manner affecting the performance of the Services or the Project, and shall give all notices required of the Consultant by law. Consultant shall be liable, pursuant to the standard of care and indemnification provisions of this Agreement, for all violations of such laws and regulations in connection with its Services. Consultant shall defend, indemnify and hold City, its officials, officers, employees and agents free and harmless, pursuant to the indemnification provisions of this Agreement, from any claim or liability arising out of any failure or alleged failure to comply with such laws, rules or regulations.
3.5.2 Drawings and Specifications. Consultant shall cause all drawings and specifications to conform to any applicable requirements of federal, state and local laws, rules and regulations, including the Uniform Building Code, in effect as of the time the drawings and specifications are prepared or revised during the latest phase of the Services described in Exhibit “A” attached hereto. Any significant revisions made necessary by changes in such laws, rules and regulations after this time may be compensated as Additional Services which were not knownor reasonably should not have been known by Consultant. Consultant shall cause the necessary copies of such drawings and specifications to be filed with any governmental bodies with approval jurisdiction over the Project, in accordance with the Services described in Exhibit “A” attached hereto. For the preparation of all such drawings and specifications, the Consultant shall use Computer Aided Design Drafting (“CADD”) (e.g., AutoCAD) or other technology acceptable to the Consultant and City.
3.5.3 Americans with Disabilities Act. Consultant will use its best professional efforts to interpret all applicable federal, state and local laws, rules and regulations with respect to access, including those of the Americans with Disabilities Act (“ADA”). Consultant shall inform City of the existence of inconsistencies of which it is aware or reasonably should be aware between federal and state accessibility laws, rules and regulations, as well as any other issues which are subject to conflicting interpretations of the law, and shall provide the City with its interpretation of such inconsistencies and conflicting interpretations. Unless Consultant brings such inconsistencies and conflicting interpretations to the attention of the City and requests City’s direction on how to proceed, the Consultant’s interpretation of such inconsistencies and conflicting interpretations shall be the sole responsibility and liability of Consultant, and the Consultant shall correct all plans, specifications and other documents prepared for the Project at no additional cost if its interpretations are shown to be incorrect. In the event that the Consultant request’s City’s direction on how to proceed with respect to any inconsistent and/or conflicting interpretation, the Consultant shall be responsible to the City only pursuant to the indemnification provisions of this Agreement.
3.5.4 Permits, Approvals and Authorizations. Consultant shall provide City with a list of all permits, approvals or other authorizations required for the Project from all federal, stateor local governmental bodies with approval jurisdiction over the Project. Consultant shall then assist the City in obtaining all such permits, approvals and other authorizations. The costs of such permits, approvals and other authorizations shall be paid by the City.
3.5.5 Water Quality Management and Compliance. Consultant shall keep itself 589
BB&K (2023)
46700.00100\40935196.1
-5-
and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Services including, without limitation, all applicable provisions of the City’s ordinances regulating water quality and storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251 et seq.); the California Porter-Cologne Water Quality Control Act (Cal Water Code §§ 13000- 14950); and any and all regulations, policies, or permits issued pursuant to any such authority.
Consultant shall additionally comply with the lawful requirements of the City, and any other municipality, drainage district, or other local agency with jurisdiction over the location where the Services are to be conducted, regulating water quality and storm water discharges. Failure to comply with laws, regulations, and ordinances listed in this Section is a violation of federal and state law.
3.6 Independent Contractor.
3.6.1 Control and Payment of Subordinates. City retains Consultant on an independent contractor basis and Consultant is not an employee of City. Consultant is not an employee for state tax, federal tax or any other purpose, and is not entitled to the rights or benefits afforded to City’s employees. Any additional personnel performing the Services under this Agreement on behalf of Consultant shall also not be employees of City, and shall at all times be under Consultant’s exclusive direction and control. Consultant shall pay all wages, salaries, and other amounts due such personnel in connection with their performance of Services under this Agreement and as required by law. Consultant shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers’ compensation insurance.
3.7 Schedule of Services.
3.7.1 Consultant Services. Consultant shall fully and adequately complete the Services described in this Agreement and in Exhibit “A” attached hereto and incorporated herein by reference.
3.7.2 Timely Performance Standard. Consultant shall perform all Services hereunder as expeditiously as is consistent with professional skill and care, as well as the orderly progress of the Project work so as not to be the cause, in whole or in part, of delays in the completion of the Project or in the achievement of any Project milestones, as provided herein.
Specifically, Consultant shall perform its Services so as to allow for the full and adequate completion of the Project within the time required by the City and within any completion schedules adopted for the Project. Consultant agrees to coordinate with City’s staff, contractors and consultants in the performance of the Services, and shall be available to City’s staff, contractors and consultants at all reasonable times.
3.7.3 Performance Schedule. Consultant shall prepare an estimated time schedule for the performance of Consultant’s Services, to be adjusted as the Project proceeds.
Such schedule shall be subject to the City’s review and approval, which approval shall not be unreasonably withheld, and shall include allowances for periods of time required for City’s review and approval of submissions, and for approvals of authorities having jurisdiction over Project approval and funding. If City and Consultant cannot mutually agree on a performance schedule, City shall have the authority to immediately terminate this Agreement. The schedule shall not be exceeded by Consultant without the prior written approval of City. If the Consultant’s Services are not completed within the time provided by the agreed upon performance schedule, or any 590
BB&K (2023)
46700.00100\40935196.1
-6-
milestones established therein, it is understood, acknowledged and agreed that the City will suffer damage for which the Consultant will be responsible.
3.7.4 Excusable Delays. Any delays in Consultant’s work caused by the following may be added to the time for completion of any obligations of Consultant: (1) the actionsof City or its employees; (2) the actions of those in direct contractual relationship with City; (3) theactions of any governmental agency having jurisdiction over the Project; (4) the actions of any parties not within the reasonable control of the Consultant; and (5) any Force Majeure Event (asdefined herein) or other unforeseen occurrence not due to any fault or negligence on the part of Consultant. Neither the City nor the Consultant shall be liable for damages, liquidated or otherwise, to the other on account of such delays.
3.7.5 Force Majeure Events. Neither City nor Consultant shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the non-performing Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Consultant and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the Services and Agreement. Should a Force Majeure Event occur, the nonperforming Party shall, within fifteen (15) calendar days of the beginning of an Force Majeure Event, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events shall not entitle Consultant to any additional compensation. Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement.
3.7.6 Request for Excusable Delay Credit. The Consultant shall, within fifteen (15) calendar days of the beginning of any excusable delay, notify the City in writing of the causes of delay (unless City grants in writing a further period of time to file such notice prior to the date of final payment under the Agreement). City will then ascertain the facts and the extent of the delay, and grant an extension of time for completing the Services when, in its sole judgment, the findings of fact justify such an extension. The City’s findings of fact thereon shall be final and conclusive on the Parties. Extensions of time shall apply only to that portion of the Services affected by the delay and shall not apply to other portions of the Services not so affected. The sole remedy of Consultant for extensions of time shall be an extension of the performance time at no cost to the City. If Additional Services are required as a result of an excusable delay, the Parties shall mutually agree thereto pursuant to the Additional Services provision of this Agreement. Should Consultant make an application for an extension of time, Consultant shall submit evidence that the insurance policies required by this Agreement remain in effect during the requested additional period of time.
591
BB&K (2023)
46700.00100\40935196.1
-7-
3.8 Additional Services.
3.8.1 Request for Services. At City’s request, Consultant may be asked to perform services not otherwise included in this Agreement, not included within the basic services listed in Exhibit “A” attached hereto, and/or not customarily furnished in accordance with generally accepted architectural practice.
3.8.2 Definition. As used herein, “Additional Services” mean: (1) any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary for the Consultant to perform at the execution of this Agreement; or (2) any work listed as Additional Services in Exhibit “A” attached hereto. Consultant shall not perform, nor be compensated for, Additional Services without prior written authorization from City and without an agreement between the City and Consultant as to the compensation to be paid for such services. City shall pay Consultant for any approved Additional Services, pursuant to the compensation provisions herein, so long as such services are not made necessary through the fault of Consultant pursuant to the indemnification provision of this Agreement.
3.8.3 Examples of Additional Services. Such Additional Services shall notinclude any redesign or revisions to drawings, specifications or other documents when such revisions are necessary in order to bring such documents into compliance with applicable laws, rules, regulations or codes of which Consultant was aware or should have been aware pursuantto the laws and regulations provision of this Agreement above. Such Additional Services may include, but shall not be limited to:
(a) Separately Bid Portions of Project. Plan preparation and/or administration of work on portions of the Project separately bid. (b) Furniture and Interior Design. Assistance to City, if requested, for the selection of moveable furniture, equipment or articles which are not included in the Construction Documents.
(c) Fault of Contractor. Services caused by delinquency, default or insolvency of contractor, or by major defects in the work of the contractor, provided that any such services made necessary by the failure of Consultant to detect and report such matters when it reasonably should have done so shall not be compensated. (d) Inconsistent Approvals or Instructions. Revisions in drawings, specifications or other documents when such revisions are inconsistent with written approvals or instructions previously given and are due to causes beyond the control of Consultant. (e) Legal Proceedings. Serving as an expert witness on City's behalf or attending legal proceedings to which the Consultant is not a party. (f) Damage Repair. Supervision of repair of damages to any structure. (g) Extra Environmental Services. Additional work required for environmental conditions (e.g. asbestos or site conditions) not already contemplated within the Consultant's services for the Project.
592
BB&K (2023)
46700.00100\40935196.1
-8-
3.9 City Responsibilities. City’s responsibilities shall include the following:
3.9.1 Data and Information. City shall make available to Consultant all necessary data and information concerning the purpose and requirements of the Project, including scheduling and budget limitations, objectives, constraints and criteria. As part of the budget limitation information, the City shall provide the Consultant with a preliminary construction budget (“City’s Preliminary Construction Budget”).
3.9.2 Project Survey. If required pursuant to the scope of the Project and if requested by Consultant, City shall furnish Consultant with, or direct Consultant to procure at City’s expense, a survey of the Project site prepared by a registered surveyor or civil engineer, any other record documents which shall indicate existing structures, land features, improvements, sewer, water, gas, electrical and utility lines, topographical information and boundary dimensions of the site, and any other such pertinent information.
3.9.3 Bid Phase. Distribute Construction Documents to bidders and conduct the opening and review of bids for the Project.
3.9.4 Testing. Retain consultant(s) to conduct chemical, mechanical, soils, geological or other tests required for proper design of the Project, and furnish such surveys, borings, test pits, and other tests as may be necessary to reveal conditions of the site which must be known to determine soil condition or to ensure the proper development of the required drawings and specifications.
3.9.5 Required Inspections and Tests. Retain consultant(s) to conduct materials testing and inspection or environmental/hazardous materials testing and inspection pursuant to any applicable laws, rules or regulations.
3.9.6 Fees of Reviewing or Licensing Agencies. Directly pay or reimburse the payment of all fees required by any reviewing or licensing agency, or other agency having approval jurisdiction over the Project.
3.9.7 City’s Representative. The City hereby designates the City Manager, or his or her designee, to act as its representative for the performance of this Agreement (“City’s Representative”). City’s Representative shall have the power to act on behalf of the City for all purposes under this Contract. The City Manager hereby designates Tito Haes , Executive Director Public Works, or his or her designee, as the City’s contact for the implementation of the Services hereunder. Contractor shall not accept direction or orders from any person other than the City’s Representative or his or her designee.
3.9.8 Review and Approved Documents. Review all documents submitted by Consultant, including change orders and other matters requiring approval by the City Council or other officials. City shall advise Consultant of decisions pertaining to such documents within a reasonable time after submission, so as not to cause unreasonable delay as provided in the excusable delay provisions of this Agreement above.
3.10 Compensation.
3.10.1 Consultant’s Compensation for Basic Services. City shall pay to Consultant, for the performance of all Services rendered under this Agreement, the total not to exceed amount of One Hundred Fifty Thousand Dollars ($150,000) (“Total Compensation”). 593
BB&K (2023)
46700.00100\40935196.1
-9-
This Total Compensation amount shall be based upon, and may be adjusted according to, the fee schedule and related terms and conditions attached hereto as Exhibit “B” and incorporated herein by reference. The Total Compensation, as may be adjusted upon mutual agreement, shall constitute complete and adequate payment for Services under thisAgreement.
3.10.2 Payment for Additional Services. At any time during the term of this Agreement, City may request that Consultant perform Additional Services. As used herein, Additional Services means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement. Any additional work in excess of this amount must be approved by the City. If authorized, such Additional Services will be compensated at the rates and in the manner set forth in Exhibit “B” attached hereto and incorporated herein by reference, unless a flat rate or some other form of compensation is mutually agreed upon by the Parties. IfCity requires Consultant to hire consultants to perform any Additional Services, Consultant shall be compensated therefore at the rates and in the manner set forth in Exhibit “B” attached heretoand incorporated herein by reference, unless a flat rate or some other form of compensation is mutually agreed upon by the Parties. City shall have the authority to review and approve the rates of any such consultants. In addition, Consultant shall be reimbursed for any expenses incurred by such consultants pursuant to the terms and conditions of Section 3.10.3.
3.10.3 Reimbursable Expenses. Reimbursable expenses are in addition to compensation for the Services and Additional Services. Consultant shall not be reimbursed for any expenses unless authorized in writing by City, which approval may be evidenced by inclusion in Exhibit “B” attached hereto. Such reimbursable expenses shall include only those expenses which are reasonably and necessarily incurred by Consultant in the interest of the Project.
Consultant shall be required to acquire prior written consent in order to obtain reimbursement for the following: (1) extraordinary transportation expenses incurred in connection with the Project; (2) out-of-town travel expenses incurred in connection with the Project; (3) fees paid for securing approval of authorities having jurisdiction over the Project; (4) bid document duplication costs in excess of $1,000; and (5) other costs, fees and expenses in excess of $1,000.
3.10.4 Payment to Consultant. Consultant’s compensation and reimbursable expenses shall be paid by City to Consultant no more often than monthly. Such periodic payments shall be made based upon the percentage of work completed, and in accordance with the phasing and funding schedule provided in Exhibit “B” and the compensation rates indicated in Exhibit “B” attached hereto and incorporated herein by reference. In order to receive payment, Consultant shall present to City an itemized statement which indicates Services performed, percentage of Services completed, method for computing the amount payable, and the amount to be paid. The statement shall describe the amount of Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement, as well as those expenses for which reimbursement is requested for that statement period. The amount paid to Consultant shall never exceed the percentage amounts authorized by the phasing and funding schedule located in Exhibit “B” attached hereto. City shall, within thirty (30) days of receiving such statement, review the statement and pay all approved charges thereon pursuant to the provisions of Civil Code Section 3320. Disputed amounts shall be resolved by the Parties in a mutually agreeable manner.
Payments made for Additional Services shall be made in installments, not more often than monthly, proportionate to the degree of completion of such services or in such other manner as the Parties shall specify when such services are agreed upon, and in accordance with any authorized fee or rate schedule. In order to receive payment, Consultant shall present to City an 594
BB&K (2023)
46700.00100\40935196.1
-10-
itemized statement which indicates the Additional Services performed, percentage of Additional Services completed, method for computing the amount payable, and the amount to be paid. The statement shall describe the amount of Additional Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement. City shall, within thirty (30) days of receiving such statement, review the statement and pay all approved charges thereon pursuant to the provisions of Civil Code Section 3320. Disputed amounts shall be resolved by the Parties in a mutually agreeable manner.
Upon cancellation or termination of this Agreement, Consultant shall be compensated as set forth in the termination provision herein.
3.10.5 Withholding Payment to Consultant. The City may withhold payment, in whole or in part, to the extent reasonably necessary to protect the City from claims, demands, causes of action, costs, expenses, liabilities, losses, damages, or injuries of any kind to the extent arising out of or caused by the negligence, recklessness, or willful misconduct protected under the indemnification provisions of this Agreement. Failure by City to deduct any sums from a progress payment shall not constitute a waiver of the City’s right to such sums. The City may keep any moneys which would otherwise be payable at any time hereunder and apply the same,or so much as may be necessary therefor, to the payment of any expenses, losses, or damagesas determined by the City, incurred by the City for which Consultant is liable under the Agreementor state law. Payments to the Consultant for compensation and reimbursable expenses due shallnot be contingent on the construction, completion or ultimate success of the Project. Payment tothe Consultant shall not be withheld, postponed, or made contingent upon receipt by the City of offsetting reimbursement or credit from Parties not within the Consultant’s reasonable control.
3.10.6 Prevailing Wages. Consultant is aware of the requirements of California Labor Code Sections 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., (“Prevailing Wage Laws”), which require the payment of prevailing wage rates and the performance of other requirements on certain “public works” and “maintenance” projects. If the Services are being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and if the total compensation is $1,000 or more, Consultant agrees to fully complywith and to require its consultants to fully comply with such Prevailing Wage Laws. City shall provide Consultant with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Consultant shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services available to interested parties upon request, and shall post copies at the Consultant’s principal place of business and at the Project site. It shall be mandatory upon the Consultant and all subconsultants to comply with all California Labor Code provisions, which include but are not limited to prevailing wages (Labor Code Sections 1771, 1774 and 1775), employment of apprentices (Labor Code Section 1777.5), certified payroll records (Labor Code Sections 1771.4and 1776), hours of labor (Labor Code Sections 1813 and 1815) and debarment of contractors and subcontractors (Labor Code Section 1777.1). The requirement to submit certified payroll records directly to the Labor Commissioner under Labor Code section 1771.4 shall not apply to work performed on a public works project that is exempt pursuant to the small project exemption specified in Labor Code Section 1771.4. Consultant shall defend, indemnify and hold the City, itselected officials, officers, employees and agents free and harmless from any claims, liabilities, costs, penalties or interest arising out of any failure or alleged failure of the Consultant or its consultants to comply with the Prevailing Wage Laws. (a) Registration/DIR Compliance. If the Services are being performed as part of an applicable “public works project” of over $25,000 when the project is for construction, 595
BB&K (2023)
46700.00100\40935196.1
-11-
alteration, demolition, installation, or repair work, or a public works project of over $15,000 when the project is for maintenance work, in addition to the foregoing, then pursuant to Labor Code sections 1725.5 and 1771.1, the Consultant and all subconsultants performing such Services must be registered with the Department of Industrial Relations (“DIR”). Consultant shall maintain registration for the duration of the Project and require the same of any subconsultants. This project may also be subject to compliance monitoring and enforcement by the DIR. It shall be Consultant’s sole responsibility to comply with all applicable registration and labor compliance requirements, including the submission of payroll records directly to the DIR. Any stop orders issued by the Department of Industrial Relations against Consultant or any subconsultant that affect Consultant’s performance of services, including any delay, shall be Consultant’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Consultant caused delay and shall not be compensable by the City. Consultant shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the Department of Industrial Relations against Consultant or any subconsultant.
3.11 Notice to Proceed.
Consultant shall not proceed with performance of any Services under this Agreement unless and until the City provides a written notice to proceed.
3.12 Termination, Suspension and Abandonment.
3.12.1 Grounds for Termination; Consultant’s Termination for Cause. City hereby reserves the right to suspend or abandon, at any time and for any reason, all or any portion of the Project and the construction work thereon, or to terminate this Agreement at any time with or without cause. Consultant shall be provided with at least seven (7) days advanced written notice of such suspension, abandonment or termination. In the event of such suspension, abandonment or termination, Consultant shall be paid for Services and reimbursable expenses rendered up to the date of such suspension, abandonment or termination, pursuant to the schedule of payments provided for in this Agreement, less any claims against or damages suffered by City as a result of the default, if any, by Consultant. Consultant hereby expressly waives any and all claims for damages or compensation arising under this Agreement, except as set forth herein, in the event of such suspension, abandonment or termination. Consultant may terminate this Agreement for substantial breach of performance by the City such as failure to make payment to Consultant as provided in this Agreement.
3.12.2 City’s Suspension of Work. If Consultant’s Services are suspended by City, City may require Consultant to resume such Services within ninety (90) days after written notice from City. When the Project is resumed, the Total Compensation and schedule of Services shall be equitably adjusted upon mutual agreement of the City and Consultant.
3.12.3 Documents and Other Data. Upon suspension, abandonment or termination, Consultant shall provide to City all preliminary studies, sketches, working drawings, specifications, computations, and all other Project Documents, as defined below, to which City would have been entitled at the completion of Consultant’s Services under this Agreement. Upon payment of the amount required to be paid to Consultant pursuant to the termination provisions of this Agreement, City shall have the rights, as provided in this Agreement hereinafter, to use such Project Documents prepared by or on behalf of Consultant under this Agreement. Consultant shall make such documents available to City upon request and without additional compensation other than as may be approved as a reimbursable expense. 596
BB&K (2023)
46700.00100\40935196.1
-12-
3.12.4 Employment of other Consultants. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated.
3.13 Ownership and Use of Documents; Confidentiality.
3.13.1 Ownership. All plans, specifications, original or reproducibletransparencies of working drawings and master plans, preliminary sketches, architectural presentation drawings, structural computations, estimates and any other documents prepared pursuant to this Agreement, including, but not limited to, any other works of authorship fixed in any tangible medium of expression such as writings, physical drawings and data magnetically orotherwise recorded on computer diskettes (hereinafter referred to as the “Project Documents”) shall be and remain the property of City. Although the official copyright in all Project Documentsshall remain with the Consultant or other applicable subcontractors or consultants, the Project Documents shall be the property of City whether or not the work for which they were made is executed or completed. Within thirty (30) calendar days following completion of the Project, Consultant shall provide to City copies of all Project Documents required by City. In addition, Consultant shall retain copies of all Project Documents on file for a minimum of fifteen (15) years following completion of the Project, and shall make copies available to City upon the payment ofreasonable duplication costs. Before destroying the Project Documents following this retention period, Consultant shall make a reasonable effort to notify City and provide City with the opportunity to obtain the documents.
3.13.2 Right to Use. Consultant grants to City the right to use and reuse all or part of the Project Documents, at City’s sole discretion and with no additional compensation to Consultant, for the following purposes:
(a) The construction of all or part of this Project.
(b) The repair, renovation, modernization, replacement, reconstruction or expansion of this Project at any time;
(c) The construction of another project by or on behalf of the City for its ownership and use;
City is not bound by this Agreement to employ the services of Consultant in the event such documents are used or reused for these purposes. City shall be able to use or reuse the Project Documents for these purposes without risk of liability to the Consultant or third parties with respect to the condition of the Project Documents, and the use or reuse of the Project Documents for these purposes shall not be construed or interpreted to waive or limit City’s right to recover for latent defects or for errors or omissions of the Consultant.
Any use or reuse by City of the Project Documents on any project other than this Project without employing the services of Consultant shall be at City’s own risk with respect to third parties. If City uses or reuses the Project Documents on any project other than this Project, it shall remove the Consultant’s seal from the Project Documents and hold harmless Consultant and its officers, directors, agents and employees from claims arising out of the negligent use or re-use of the Project Documents on such other project.
3.13.3 License. This Agreement creates a non-exclusive and perpetual license for 597
BB&K (2023)
46700.00100\40935196.1
-13-
City to copy, use, modify or reuse any and all Project Documents and any intellectual property rights therein. Consultant shall require any and all subcontractors and consultants to agree in writing that City is granted a non-exclusive and perpetual license for the work of such subcontractors or consultants performed pursuant to this Agreement.
3.13.4 Right to License. Consultant represents and warrants that Consultant has the legal right to license any and all copyrights, designs and other intellectual property embodied in the Project Documents that Consultant prepares or causes to be prepared pursuant to this Agreement. Consultant shall indemnify and hold City harmless pursuant to the indemnification provisions of this Agreement for any breach of this Section. Consultant makes no such representation and warranty in regard to previously prepared designs, plans, specifications, studies, drawings, estimates or other documents that were prepared by design professionals other than Consultant and provided to Consultant by City.
3.13.5 Confidentiality. All Project Documents, either created by or provided to Consultant in connection with the performance of this Agreement, shall be held confidential by Consultant to the extent they are not subject to disclosure pursuant to the Public Records Act. All Project Documents shall not, without the written consent of City, be used or reproduced by Consultant for any purposes other than the performance of the Services. Consultant shall not disclose, cause or facilitate the disclosure of the Project Documents to any person or entity not connected with the performance of the Services or the Project. Nothing furnished to Consultant which is otherwise known to Consultant or is generally known, or has become known, to the related industry shall be deemed confidential. Consultant shall not use City’s name or insignia, photographs of the Project, or any publicity pertaining to the Services or the Project in any magazine, trade paper, newspaper, television or radio production or other similar medium without the written consent of City.
3.14 Indemnification.
3.14.1 To the fullest extent permitted by law, Consultant shall defend (with counsel of City’s choosing), indemnify and hold the City, its officials, officers, employees, volunteers, and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Consultant, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Consultant’s Services, the Project or this Agreement, including without limitation the payment of all damages, expert witness fees and attorney’s fees and other related costs and expenses except such loss or damage caused by the sole negligence or willful misconduct of the City. Consultant's obligation to indemnify shall survive expiration or termination of this Agreement and shall not be restricted to insurance proceeds, if any, received by Consultant, the City, its officials, officers, employees, agents, or volunteers.
3.14.2 If Consultant’s obligation to defend, indemnify, and/or hold harmless arises out of Consultant’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Consultant’s indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Consultant, and, upon Consultant obtaining a final adjudication by a court of competent jurisdiction, Consultant’s liability for such claim, including the cost to defend, shall not exceed the Consultant’s proportionate percentage of fault.
598
BB&K (2023)
46700.00100\40935196.1
-14-
3.15 Insurance. Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this Section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurancerequired under this section.
3.15.1 Types of Insurance Required. As a condition precedent to the effectiveness of this Agreement for work to be performed hereunder, and without limiting the indemnity provisions of the Agreement, Consultant shall, at its expense, procure and maintain infull force and effect for the duration of the Agreement the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Consultant agrees to amend, supplement or endorse the policies to do so.
3.15.2 Additional Insured. The City of Ontario, its officials, officers, employees, agents, and volunteers shall be named as additional insureds on Consultant’s and its subconsultants’ policies of commercial general liability and automobile liability insurance using the endorsements and forms specified herein or exact equivalents.
3.15.3 Commercial General Liability
(a) The Consultant shall take out and maintain, during the performance of all work under this Agreement, in amounts not less than specified herein, Commercial General Liability Insurance, in a form and with insurance companies acceptable to the City. (b) Coverage for Commercial General Liability insurance shall be at least as broad as the following: Insurance Services Office Commercial General Liability coverage (Occurrence Form CG 00 01) or exact equivalent. Commercial General Liability Insurance must include coverage for the following:
(i) Bodily Injury and Property Damage
(ii) Personal Injury/Advertising Injury
(iii) Premises/Operations Liability
(iv) Products/Completed Operations Liability
(v) Aggregate Limits that Apply per Project
(vi) Explosion, Collapse and Underground (UCX) exclusion deleted
(vii) Contractual Liability with respect to this Contract (viii) Broad Form Property Damage
(ix) Independent Consultants Coverage
(c) The policy shall contain no endorsements or provisions limiting coverage for (1) contractual liability; (2) cross liability exclusion for claims or suits by one insured against another; (3) products/completed operations liability; or (4) contain any other exclusion 599
BB&K (2023)
46700.00100\40935196.1
-15-
contrary to the Agreement.
(d) The policy shall give City, the City Council and each member of the City Council, its officers, employees, agents and City designated volunteers additional insured status using ISO endorsement forms CG 20 10 10 01 and 20 37 10 01, or endorsements providing the exact same coverage.
(e) The general liability program may utilize either deductibles or provide coverage excess of a self-insured retention, subject to written approval by the City, and provided that such deductibles shall not apply to the City as an additional insured.
3.15.4 Automobile Liability
(a) At all times during the performance of the work under this Agreement, the Consultant shall maintain Automobile Liability Insurance for bodily injury and property damage including coverage for owned, non-owned and hired vehicles, in a form and with insurance companies acceptable to the City.
(b) Coverage for automobile liability insurance shall be at least as broad as Insurance Services Office Form Number CA 00 01 covering automobile liability (Coverage Symbol 1, any auto).
(c) The policy shall give City, the City Council and each member of the City Council, its officers, employees, agents and City designated volunteers additional insured status.
(d) Subject to written approval by the City, the automobile liability program may utilize deductibles, provided that such deductibles shall not apply to the City as an additional insured, but not a self-insured retention.
3.15.5 Workers’ Compensation/Employer’s Liability
(a) Consultant certifies that he/she is aware of the provisions of Section 3700 of the California Labor Code which requires every employer to be insured against liability for workers’ compensation or to undertake self-insurance in accordance with the provisions of that code, and he/she will comply with such provisions before commencing work under this Agreement.
(b) To the extent Consultant has employees at any time during the term of this Agreement, at all times during the performance of the work under this Agreement, the Consultant shall maintain full compensation insurance for all persons employed directly by him/her to carry out the work contemplated under this Agreement, all in accordance with the “Workers’ Compensation and Insurance Act,” Division IV of the Labor Code of the State of California and any acts amendatory thereof, and Employer’s Liability Coverage in amounts indicated herein. Consultant shall require all subconsultants to obtain and maintain, for the period required by this Agreement, workers’ compensation coverage of the same type and limits as specified in this Section.
3.15.6 Professional Liability (Errors and Omissions)
(a) At all times during the performance of the work under this 600
BB&K (2023)
46700.00100\40935196.1
-16-
Agreement the Consultant shall maintain professional liability or Errors and Omissions insurance appropriate to its profession, in a form and with insurance companies acceptable to the City and in an amount indicated herein. This insurance shall be written on a policy form coverage specifically designed to protect against acts, errors or omissions of the Consultant. “Covered Professional Services” as designated in the policy must specifically include work performed under this Agreement. The policy must “pay on behalf of” the insured and must include a provision establishing the insurer's duty to defend.
3.15.7 Minimum Policy Limits Required
(a) The following insurance limits are required for the Agreement:
Coverage Combined Single Limit
Commercial General Liability $2,000,000 per occurrence/ $4,000,000 aggregate for bodily injury, personal
injury, and property damage
Automobile Liability $2,000,000 per occurrence for bodily injury and property damage
Employer’s Liability $1,000,000 per occurrence
Professional Liability $2,000,000 per claim and aggregate (errors and omissions)
(b) Defense costs shall be payable in addition to the limits. (c) Requirements of specific coverage or limits contained in this Section are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance. Any available coverage shall be provided to the parties required to be named as Additional Insured pursuant to this Agreement.
3.15.8 Evidence Required
(a) Prior to execution of the Agreement, the Consultant shall file with the City evidence of insurance from an insurer or insurers certifying to the coverage of all insurance required herein. Such evidence shall include original copies of the ISO CG 00 01 (or insurer’s equivalent) signed by the insurer’s representative and Certificate of Insurance (Acord Form 25-S or equivalent), together with required endorsements. All evidence of insurance shall be signed by a properly authorized officer, agent, or qualified representative of the insurer and shall certify the names of the insured, any additional insureds, where appropriate, the type and amount of the insurance, the location and operations to which the insurance applies, and the expiration date of such insurance.
3.15.9 Policy Provisions Required
(a) Consultant shall provide the City at least thirty (30) days prior written notice of cancellation of any policy required by this Agreement, except that the Consultantshall provide at least ten (10) days prior written notice of cancellation of any such policy due to nonpayment of premium. If any of the required coverage is cancelled or expires during the termof this Agreement, the Consultant shall deliver renewal certificate(s) including the General Liability 601
BB&K (2023)
46700.00100\40935196.1
-17-
Additional Insured Endorsement to the City at least ten (10) days prior to the effective date of cancellation or expiration.
(b) The Commercial General Liability Policy and Automobile Policy shall each contain a provision stating that Consultant’s policy is primary insurance and that any insurance, deductible, or self-insurance maintained by the City, its officials, officers, employees, agents, or volunteers shall not contribute with this primary insurance. Policies shall contain or be endorsed to contain such provisions.
(c) The retroactive date (if any) of each policy is to be no later than the effective date of this Agreement. Consultant shall maintain such coverage continuously for a period of at least three years after the completion of the work under this Agreement. Consultant shall purchase a one (1) year extended reporting period A) if the retroactive date is advanced past the effective date of this Agreement; B) if the policy is cancelled or not renewed; or C) if thepolicy is replaced by another claims-made policy with a retroactive date subsequent to the effective date of this Agreement.
(d) All required insurance coverages, except for the professional liability coverage, shall contain or be endorsed to waiver of subrogation in favor of the City, its officials, officers, employees, agents, and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these specifications to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants.
(e) The limits set forth herein shall apply separately to each insured against whom claims are made or suits are brought, except with respect to the limits of liability.
Further the limits set forth herein shall not be construed to relieve the Consultant from liability in excess of such coverage, nor shall it limit the Consultant’s indemnification obligations to the City and shall not preclude the City from taking such other actions available to the City under other provisions of the Agreement or law.
3.15.10 Qualifying Insurers
(a) All policies required shall be issued by acceptable insurance companies, as determined by the City, which satisfy the following minimum requirements: Each such policy shall be from a company or companies with a current A.M. Best's rating of no less than A:VII and admitted to transact in the business of insurance in the State of California, or otherwise allowed to place insurance through surplus line brokers under applicable provisions of the California Insurance Code or any federal law.
3.15.11 Additional Insurance Provisions
(a) The foregoing requirements as to the types and limits of insurance coverage to be maintained by Consultant, and any approval of said insurance by the City, is not intended to and shall not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Consultant pursuant to this Agreement, including but not limited to, the provisions concerning indemnification.
(b) If at any time during the life of the Agreement, any policy of insurance required under this Agreement does not comply with these specifications or is canceled and not replaced, City has the right but not the duty to obtain the insurance it deems necessary 602
BB&K (2023)
46700.00100\40935196.1
-18-
and any premium paid by City will be promptly reimbursed by Consultant or City will withhold amounts sufficient to pay premium from Consultant payments. In the alternative, City may cancel this Agreement.
(c) The City may require the Consultant to provide complete copies of all insurance policies in effect for the duration of the Project. (d) Neither the City nor the City Council, nor any member of the City Council, nor any of the officials, officers, employees, agents or volunteers shall be personally responsible for any liability arising under or by virtue of this Agreement.
3.15.12 Subconsultant Insurance Requirements
(a) Consultant shall not allow any subcontractors or subconsultants to commence work on any subcontract until they have provided evidence satisfactory to the City that they have secured all insurance required under this Section. Policies of commercial general liability insurance provided by such subcontractors or subconsultants shall be endorsed to name the City as an additional insured using ISO form CG 20 38 04 13 or an endorsement providing the exact same coverage. If requested by Consultant, City may approve different scopes or minimum limits of insurance for particular subcontractors or subconsultants.
3.16 Records.
Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to thisAgreement.
Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of five (5) years from the date of final payment under this Agreement.
3.17 Standardized Manufactured Items.
Consultant shall cooperate and consult with City in the use and selection of manufactured items on the Project, including but not limited to, paint, hardware, plumbing, mechanical and electrical equipment, fixtures, roofing materials and floor coverings. All such manufactured items shall be standardized to City’s criteria to the extent such criteria do not interfere with building design.
3.18 Limitation of Agreement.
This Agreement is limited to and includes only the work included in the Project described herein. Any additional or subsequent construction at the site of the Project, or at any other City site, will be covered by, and be the subject of, a separate Agreement for architectural services between City and the Consultant chosen therefor by City.
3.19 Mediation.
Disputes arising from this Agreement may be submitted to mediation if mutually agreeable to the Parties hereto. The type and process of mediation to be utilized shall be subject to the mutual agreement of the Parties.
603
BB&K (2023)
46700.00100\40935196.1
-19-
3.20 Successors and Assigns.
This Agreement shall be binding upon and shall inure to the benefit of the successors in interest, executors, administrators and assigns of each Party to this Agreement. However, Consultant shall not assign or transfer by operation of law or otherwise any or all of its rights, burdens, duties or obligations without the prior written consent of City. Any attempted assignment without such consent shall be invalid and void.
3.21 Asbestos Certification.
Consultant shall certify to City, in writing and under penalty of perjury, that to the best of its knowledge, information and belief no asbestos-containing material or other material deemed to be hazardous by the state or federal government was specified as a building material in any construction document that the Consultant prepares for the Project. Consultant shall require all consultants who prepare any other documents for the Project to submit the same written certification. Consultant shall also assist the City in ensuring that contractors provide City with certification, in writing and under penalty of perjury, that to the best of their knowledge, information and belief no material furnished, installed or incorporated into the Project contains asbestos or any other material deemed to be hazardous by the state or federal government. These certifications shall be part of the final Project submittal. Consultant shall include statements in its specifications that materials containing asbestos or any other material deemed to be hazardous by the state or federal government are not to be included.
3.22 No Third Party Rights.
This Agreement shall not create any rights in, or inure to the benefits of, any third party except as expressly provided herein.
3.23 Governing Law.
This Agreement shall be construed in accordance with, and governed by, the laws of the State of California. Venue shall be in San Bernardino County.
3.24 Exhibits and Recitals.
All exhibits and recitals contained herein and attached hereto are material parts of this Agreement and are incorporated as if fully set forth.
3.25 Severability.
Should any provision in the Agreement be held by a court of competent jurisdiction to be invalid, void, or unenforceable, the remaining provisions shall continue in full force and effect.
3.26 Non-Waiver.
None of the provisions of this Agreement shall be considered waived by either Party, unless such waiver is specifically specified in writing. 604
BB&K (2023)
46700.00100\40935196.1
-20-
3.27 Safety.
Consultant shall execute and maintain its work so as to avoid injury or damage to any person or property. In carrying out its Services, the Consultant shall at all times be in compliance with all applicable local, state and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of its employees, consultant and subcontractors appropriate to the nature of the work and the conditions under which the work is to be performed.
3.28 Harassment Policy.
Consultant shall provide a copy of the City's Harassment Policy to each of its employees assigned to perform the tasks under this Agreement. Consultant shall submit to the City's Personnel Manager a statement signed by each of its employees who are assigned to perform the Services under this Agreement certifying receipt of City's Harassment Policy and certifying that they have read the Harassment Policy. A finding by the City that any of Consultant's employees has harassed a City employee shall be grounds for appropriate discipline, up to and including such employee's removal from performance of this Agreement at City's request.
3.29 Delivery of Notices.
All notices permitted or required under this Agreement shall be given to the respective Parties at the following address, or at such other address as the respective Parties may provide in writing for this purpose:
CITY:
City of Ontario
303 East “B” Street
Ontario, CA 91764
Attn: Adrian Escamilla, Design and Construction
CONSULTANT:
Westgroup Design
19900 MacArthur Blvd
Irvine, CA 92612
Attn: : PariSima Hassani, CEO
Such notice shall be deemed made when personally delivered or when mailed, forty-eight (48) hours after deposit in the U.S. Mail, first class postage prepaid and addressed to the Party at its applicable address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.
3.30 Time of Essence.
Time is of the essence for each and every provision of this Agreement.
3.31 City’s Right to Employ Other Consultants.
City reserves right to employ other consultants, including designers, in connection with this Project or other projects.
3.32 Prohibited Interests.
3.32.1 Solicitation. Consultant maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for 605
BB&K (2023)
46700.00100\40935196.1
-21-
Consultant, to solicit or secure this Agreement. Further, Consultant warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability.
3.32.2 Conflict of Interest. For the term of this Agreement, no director, official, officer or employee of City, during the term of his or her service with City, shall have any direct interest in this Agreement, or obtain any present or anticipated material benefit arising therefrom.
3.33 Equal Opportunity Employment.
Consultant represents that it is an equal opportunity employer and that it shall not discriminate against any employee or applicant for employment because of race, religion, color, national origin, ancestry, sex, age or any other classification protected by federal or state law.
Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination. Consultant shall also comply with all relevant provisions of City’s minority business enterprise program, affirmative action plan or other related programs or guidelines currently in effect or hereinafter enacted.
3.34 Labor Certification.
By its signature hereunder, Consultant certifies that it is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker’s Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services.
3.35 Subcontracting.
As specified in this Agreement, Consultant shall not subcontract any portion of the Services required by this Agreement, except as expressly stated herein, without prior written approval of City. Subcontracts, if any, shall contain a provision making them subject to each and every provision of this Agreement.
3.36 Supplemental Conditions.
Any supplemental conditions shall be attached as an exhibit to this Agreement, and that exhibit shall be incorporated herein by reference.
3.37 Entire Agreement.
This Agreement, with its exhibits, contains the entire agreement of the Parties hereto, and supersedes any and all other prior or contemporaneous negotiations, understandings and oral or written agreements between the Parties hereto. Each Party acknowledges that no representations, inducements, promises or agreements have been made by any person which are not incorporated herein, and that any other agreements shall be void. Furthermore, any modification of this Agreement shall only be effective if in writing signed by all Parties hereto.
SIGNATURES ON FOLLOWING PAGE
606
BB&K (2023)
46700.00100\40935196.1
-22-
SIGNATURE PAGE FOR DESIGN SERVICES AGREEMENT
BETWEEN THE CITY OF ONTARIO
AND WESTGROUP DESIGNS, INC.
IN WITNESS WHEREOF, the Parties have executed this Agreement as of the date first written above.
CITY OF ONTARIO Westgroup Designs, Inc.
By:
Its:
Printed Name:
By:
Its:
Printed Name:
[If Corporation, TWO SIGNATURES,
President OR Vice President AND Secretary
OR Treasurer REQUIRED]
Approved By:
Scott Ochoa
City Manager
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:
City Clerk
607
BB&K (2023)
46700.00100\40935196.1
Exhibit A-1
EXHIBIT “A”
SCOPE OF SERVICES
1. GENERAL REQUIREMENTS.
1.1 Basic Services. Consultant agrees to perform all the necessary professional architectural, engineering (e.g. mechanical, electrical, plumbing, structural, site engineering, and any other necessary engineering services mutually agreeable to the Parties) and construction administration services for the Project in a timely and professional manner, consistent with the standards of the profession, including those provided for herein.
1.2 Exclusions from Basic Services. The following services shall be excluded from the basic services listed above: Exclusions will be determined on a project-by-project basis.
1.3 Additional Services. Consultant shall perform the following Additional Services for the Project: Additional Services will be determined on a project by project.
1.4 Communication with City. Consultant shall participate in consultations and conferences with authorized representatives of City and/or other local, regional, or state agencies concerned with the Project, which may be necessary for the completion of the Project or the development of the drawings, specifications and documents in accordance with the applicable standards and requirements of law and the City. Such consultations and conferences shall continue throughout the planning and construction of the Project and the contractor’s warranty period. Consultant shall take direction only from the City’s Representative, or any other representative specifically designated by the City for this Project, including any construction manager hired by the City.
1.5 Coordination and Cooperation with Construction Manager. The City may hire a construction manager to administer and coordinate all or any part of the Project on its behalf. If the City does so, it shall provide a copy of its agreement with the construction manager so that the Consultant will be fully aware of the duties and responsibilities of the construction manager.
The Consultant shall cooperate with the construction manager and respond to any requests or directives authorized by the City to be made or given by the construction manager. The Consultant shall request clarification from the City in writing if the Consultant should have any questions regarding the authority of the construction manager.
2. INITIAL PLANNING PHASE.
During the initial planning phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
2.1 Project Feasibility. Provide advice and assistance to City in determining the feasibility of the Project, analysis of the type and quality of materials and construction to be selected, the site location, and other initial planning matters.
2.2 Meeting Budget and Project Goals. Consultant shall notify City in writing of potential complications, cost overruns, unusual conditions, and general needs that potentially impact the Project budget and time line, including the City’s Preliminary Construction Budget.
Consultant shall use its best judgment in determining the balance between the size, type and 608
BB&K (2023)
46700.00100\40935196.1
Exhibit A-2
quality of construction to achieve a satisfactory solution within the Project’s budget and construction allowance. It shall be the duty of the Consultant to design the Project within budget.
As discussed herein, including in Section 7.3, if the lowest responsive and responsible bid for the Project exceeds the budget by the stated amount, Consultant may be required to make the necessary changes in the drawing and specifications, at its sole cost and expense, to bring the bids within the required budget.
2.3 Permits, Approvals and Authorizations. As indicated in Section 3.5.4 of the Agreement, Consultant shall assist City in securing easements, encroachment permits, rights of way, dedications, infrastructures and road improvements, as well as coordinating with utilities and adjacent property owners.
3. SCHEMATIC PLAN PHASE.
During the schematic plan phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
3.1 Funding Documents. Consultant shall provide a site plan and all other Projectrelated information necessary and required for an application by City to any federal, state, regional, or local agencies for funds to finance the construction Project.
3.2 Schematic Plans. In cooperation with City, Consultant shall prepare preliminary plans and studies, schematic drawings, site utilization plans, and phasing plans showing the scale and relationship of the components of the Project, the plot plan development at the site, and the proposed architectural concept of the buildings (“Schematic Plans”). Consultant shall incorporate the functional requirements of City into the Schematic Plans. The Schematic Plans shall meet all laws, rules and regulations of the State of California. The Schematic Plans shall show all rooms incorporated in each building of the Project in single-line drawings, and shall include all revisions required by City or by any federal, state, regional or local agency having jurisdiction over the Project. All architectural drawings for the Project shall be in a form suitable for reproduction.
3.3 Preliminary Project Budget. Consultant shall use the City’s Preliminary Construction Budget and its own expertise and experience with the Project to establish a preliminary project budget or allowance in a format required by City (“Consultant’s Preliminary Project Budget”). The purpose of the Consultant’s Preliminary Project Budget is to show the probable Project cost in relation to City’s Preliminary Construction Budget and the construction standards of any applicable funding agency. If Consultant perceives site considerations which render the Project expensive or cost prohibitive, Consultant shall disclose such conditions in writing to City immediately. As discussed herein, including in Section 7.3, if the lowest responsive and responsible bid for the Project exceeds the budget by more than the stated amount, Consultant may be required to make the necessary changes in the drawings and specifications, at its sole cost and expense, to bring the bids within the required budget Consultant shall provide a preliminary written time schedule for the performance of all construction work on the Project.
3.4 Copies of Schematic Plans and Other Documents. Consultant, at its own expense, shall provide a complete set of the Schematic Plans described herein for City’s review and approval. Additionally, at City’s expense, Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any additional copies required by City shall be provided at actual cost to City. 609
BB&K (2023)
46700.00100\40935196.1
Exhibit A-3
4. DESIGN DEVELOPMENT PHASE.
During the design development phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
4.1 Design Development Documents. Once City provides Consultant with specific written approval of the Schematic Plans described herein, Consultant shall prepare design development documents consisting of: (1) site and floor plans; (2) elevations; and (3) any other drawings and documents sufficient to fix and describe the types and makeup of materials, as well as the size and character of the Project’s structural, mechanical and electrical systems, and to outline the Project specifications (“Design Development Documents”). The Design Development Documents shall be prepared in sufficient form to present to the City Council for approval.
4.2 Copies of Design Development and Other Documents. Consultant, at its own expense, shall provide a complete set of the Design Development Documents described herein for City’s review and approval. Additionally, at City’s expense, Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any additional copies required by City shall be provided at actual cost to City.
4.3 Updated Project Budget. Consultant shall use its Preliminary Project Budget and expertise and experience with the Project to establish an updated estimate of probable construction costs, containing detail consistent with the Design Development Documents as set forth herein and containing a breakdown based on types of materials and specifications identified herein (“Consultant’s Updated Project Budget”).
4.4 Timetable. Consultant shall provide a written timetable for full and adequate completion of the Project to City.
4.5 Application for Approvals. Consultant shall assist City in applying for and obtaining required approvals from all federal, state, regional or local agencies concerned with the Project. Consultant shall furnish and process all architectural and engineering information required to prepare and process applications to applicable utilities in order to secure priorities and materials, to aid in the construction of the Project and to obtain final Project approval and acceptance by any of the above agencies as may be required.
4.6 Color and Other Aesthetic Issues. Consultant shall provide, for City’s review and approval, a preliminary schedule of all color materials and selections of textures, finishes andother matters involving an aesthetic decision about the Project.
5. FINAL WORKING DRAWINGS AND SPECIFICATIONS.
During the final working drawings and specifications phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
5.1 Final Working Drawings and Specifications. Once City provides Consultant with specific written approval of the Design Development Documents described herein, Consultant shall prepare such complete working drawings and specifications as are necessary for developing complete bids and for properly executing the Project work in an efficient and thorough manner (“Final Working Drawings and Specifications”). Such Final Working Drawings and Specifications shall be developed from the Schematic Plans and Design Development Documents approved by City. The Final Working Drawings and Specifications shall set forth in 610
BB&K (2023)
46700.00100\40935196.1
Exhibit A-4
detail all of the following: (1) the Project construction work to be done; (2) the materials, workmanship, finishes, and equipment required for the architectural, structural, mechanical, and electrical systems; and (3) the utility service connection equipment and site work. As indicated in Section 3.9.2 of the Agreement, City may be requested to supply Consultant with the necessary information to determine the proper location of all improvements on and off site, including record drawings (“as-built drawings”) in City’s possession. Consultant will make a good-faith effort to verify the accuracy of such information by means of a thorough interior and exterior visual survey of site conditions. City shall also make a good-faith effort to verify the accuracy of the as-built drawings and provide any supplemental information to Consultant which may not be shown on the as-built drawings.
5.2 Form. The Final Working Drawings and Specifications must be in such form as will enable Consultant and City to secure the required permits and approvals from all federal, state, regional or local agencies concerned with the Project. In addition, the Final Working Drawings and Specifications must be in such form as will enable City to obtain, by competitive bidding, a responsible and responsive bid within the applicable budgetary limitations and cost standards.
The Final Working Drawings and Specifications shall be clear and legible so that uniform copies may be on standard architectural size paper, properly indexed and numbered, andshall be capable of being clearly copied and assembled in a professional manner by Consultant.
5.3 Approval and Revisions. City shall review, study, and check the Final Working Drawings and Specifications presented to it by Consultant, and request any necessary revisions or obtain any necessary approvals by the City Council, subject to the approval of all federal, state, regional or local agencies concerned with the Project. Consultant shall make all City-requested changes, additions, deletions, and corrections in the Final Working Drawings and Specifications at no additional cost, so long as they are not in conflict with the requirements of public agencies having jurisdiction or prior approval, or inconsistent with earlier City direction or Consultant’s professional judgment. Consultant shall bring any such conflicts and/or inconsistencies to the attention of City. The Parties agree that Consultant, and not the City, possesses the requisite expertise to determine the constructability of the Final Working Drawings and Specifications.
However, the City reserves the right to conduct one or more constructability review processes with the Final Working Drawings and Specifications, and to hire an independent architect or other consultant to perform such reviews. Any such independent constructability review shall be at City’s expense. Consultant shall make all City-requested changes, additions, deletions, and corrections in the Final Working Drawings and Specifications which may result from any constructability review, at no additional cost to the City, so long as they are not in conflict with the requirements of public agencies having jurisdiction or prior approval, or inconsistent with earlier City direction or Consultant’s professional judgment. If such changes, additions, deletions or corrections are inconsistent with prior City direction, Consultant shall make such alterations and be compensated therefore pursuant to the Additional Services provision of this Agreement.
5.4 Costs of Construction. It is understood by Consultant that should the Final Working Drawings and Specifications be ordered by City, City shall specify the sum of money set aside to cover the total cost of construction of the work, exclusive of Consultant’s fees. Should it become evident that the total construction cost will exceed the specified sum, Consultant shall at once present a statement in writing to the City’s Representative setting forth this fact and giving a full statement of the cost estimates on which the conclusion is based.
5.5 Copies of Final Working Drawings and Specifications and Other Documents.
Consultant, at its own expense, shall provide a complete set of the Final Working Drawings and Specifications described herein for City’s review and approval. Additionally, at City’s expense, 611
BB&K (2023)
46700.00100\40935196.1
Exhibit A-5
Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any additional copies required by City shall be provided at actual cost to City.
6. CONSTRUCTION CONTRACT DOCUMENTS.
During the construction contract documents phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
6.1 Bid and Contract Documents. If so required by City, Consultant shall assist City in the completion of all bid and construction documents, including but not limited to, the Notice Inviting Bids, Instructions to Bidders, Contract Bid Forms (including Alternate Bids as requested by City), `Contract, General Conditions, Supplementary General Conditions, Special Conditions, DVBE and other applicable affirmative action documents, Performance Bond, Payment Bond, Escrow Agreement for Security Deposits, and any other certifications and documents required by federal, state and local laws, rules and regulations which may be reasonably required in order to obtain bids responsive to the specifications and drawings. All such documents shall be subject to the approval of City and City’s legal counsel.
6.2 Final Estimate. At the time of delivery of these bid and construction documents, which shall include the Final Working Drawings and Specifications (collectively referred to herein as the “Construction Documents”), Consultant shall provide City with its final estimate of probable construction cost (“Consultant’s Final Estimate”). As discussed herein, including in Section 7.3, it shall be the Consultant’s duty to design the Project within budget.
7. BID PHASE.
During the bid phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
7.1 Reproducible Construction Documents. Once City provides Consultant with specific written approval of the Construction Documents and Consultant’s Final Estimate, Consultant shall provide to City one set of reproducible Construction Documents.
7.2 Distribution of Contract Documents and Review of Bids. Consultant shall assist City in distributing the Construction Documents to bidders and conducting the opening and review of bids for the Project.
7.3 Over Budget. If the apparent lowest responsive and responsible bid on the Project exceeds the Consultant’s Final Estimate by more than five percent (5%), City may request Consultant to amend, at Consultant’s sole cost and expense, the Final Drawings and Specifications in order to rebid the Project and receive a lowest responsive and responsible bid equal to or less than the Consultant’s Final Estimate. All revisions necessary to bring the lowest responsible and responsive bid within the Consultant’s Final Estimate, including any omissions, deferrals or alternates, shall be made in consultation with, and subject to the approval of, the City.
8. CONSTRUCTION PHASE.
During the construction phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
612
BB&K (2023)
46700.00100\40935196.1
Exhibit A-6
8.1 Observation. The Project Consultant shall observe work executed from the Final Working Drawings and Specifications in person, provided that City may, in its discretion, consent to such observation by another competent representative of Consultant.
8.2 General Administration. Consultant shall provide general administration of the Construction Documents and the work performed by the contractors.
8.3 Pre-Construction Meeting. Consultant shall conduct one or more preconstruction meetings, as the City determines is needed for the Project, with all interested Parties.
8.4 Site Visits of Contractor’s Work. Consultant shall conduct site visits to observe each contractors’ work for general conformance with the Construction Documents and with any approved construction schedules or milestones. Such site visits shall be conducted as often as are necessary and appropriate to the stage of construction, according to the City’s sole discretion, but in no event less than weekly.
8.5 Site Visits of Inspector’s Work. Consultant shall conduct site visits to communicate and observe the activities of the City inspectors. Such site visits shall be conducted as often as is mutually acceptable to Consultant and City. Consultant shall direct the City inspectors and the Project contractors to coordinate the preparation of record drawings indicating dimensions and location of all “as-built” conditions, including but not limited to, underground utility lines.
8.6 Coordination of Subconsultants. Consultant shall cause all architects, engineers and other consultants, as may be hired by Consultant or City, to observe the work completed under their disciplines as required, and approve and review all test results for general conformance with the Construction Documents.
8.7 Reports. Consultant shall make regular reports as may be required by applicable federal, state or local laws, rules or regulations, as well as the federal, state, regional or local agencies concerned with the Project.
8.8 Construction Meetings; Minutes. Consultant shall attend all construction meetings and provide written reports/minutes to the City after each construction meeting in order to keep City informed of the progress of the work. Such meetings shall occur at a frequency necessary for the progress of the Project work, according to the City’s sole discretion, but no less than weekly.
8.9 Written Reports. Consultant shall make written reports to City as necessary to inform City of problems arising during construction, changes contemplated as a result of each such problems, and progress of the Project work.
8.10 Written Records. Consultant shall keep accurate written records of the progress and quality of the Project work and the time schedules, and shall advise the contractors and City of any deviations from the time schedule which could delay timely completion of the Project.
8.11 Material and Test Reports. Consultant shall check and process, in a timely manner, all required material and test reports for the Project work. In addition, Consultant shall provide notice of any deficiencies in material or work reflected in such reports, as well as its recommendation for correction of such deficiencies, to the contractors and City. 613
BB&K (2023)
46700.00100\40935196.1
Exhibit A-7
8.12 Review and Response to Submissions. Consultant shall review and respond, in a timely manner, to all schedules, submittals, shop drawings, samples, information requests, change requests, and other submissions of the contractor and subcontractors for compliance with, or alterations and additions to, the Construction Documents. Consultant’s review and response shall be done in such a manner so as to ensure the timely and uninterrupted progress of the Project work.
8.13 Rejection of Work. Consultant shall promptly reject, as discussed with City, work or materials which do not conform to the Construction Documents. Consultant shall immediately notify the City and contractor(s) of such rejections. Consultant shall also have the authority to recommend to the City that additional inspection or testing of the work be performed, whether or not such work is fabricated, installed or completed.
8.14 Substitutions. Consultant shall consult with City, in a timely manner, with regard to substitution of materials, equipment and laboratory reports thereof, prior to the City’s final written approval of such substitutions. Consultant’s consultation shall be done in such a manner so as to ensure the timely and uninterrupted progress of the Project work.
8.15 Revised Documents and Drawings. Consultant shall prepare, at no additional expense to City, all documents and/or drawings made necessary by errors and omissions in the originally approved Construction Documents.
8.16 Change Requests and Material Changes. Consultant shall evaluate and advise City, in a timely manner and in writing, of any change requests and material change(s) which may be requested or necessary in the Project plans and specifications. Consultant shall provide the City with its opinion as to whether such change requests should be approved, denied or revised.
If the City has not hired a construction manager or other person to do so, the Consultant shall prepare and execute all change orders and submit them to the City for authorization. If the City has designated a construction manager or other person to prepare all change orders, the Consultant shall review all change orders prepared by such person, execute them and deliver them to the City for authorization if they meet with the Consultant’s approval, or submit them to the City with recommendations for revision or denial if necessary. Consultant shall not order contractors to make any changes affecting the contract price without approval by City of such a written change order, pursuant to the terms of the Construction Documents. Consultant may order, on its own responsibility and pending City Council approval, changes necessary to meet construction emergencies, if written approval of City’s Representative is first secured.
8.17 Applications for Payment. Consultant shall examine, verify and approve contractor’s applications for payment, and shall issue certificates for payment in amounts approved by the City’s inspector.
8.18 Final Color and Product Selection. Consultant shall coordinate final color and product selection with City’s original design concept.
8.19 Substantial Completion. Consultant shall determine the date of substantial completion, in consultation with the City.
8.20 Punch List. After determining that the Project is substantially complete, Consultant shall participate in the inspection of the Project and shall review all remaining deficiencies and minor items needed to be corrected or completed on the Project, including those identified on the punch list prepared by the contractor (“Punch List Items”). Consultant shall notify 614
BB&K (2023)
46700.00100\40935196.1
Exhibit A-8
contractor in writing that all Punch List Items must be corrected prior to final acceptance of the Project and final payment. Consultant shall also notify City of all Punch List Items.
8.21 Warranties. Consultant shall review materials assembled by the contractor and subcontractors with regard to all written warranties, guarantees, owners’ manuals, instruction books, diagrams, record “as built” drawings, and any other materials required from the contractors and subcontractors pursuant to the Construction Documents. Consultant shall coordinate and provide these materials to the City.
8.22 Certificate of Completion. Consultant shall participate in any further inspections of the Project necessary to issue Consultant’s Certificate of Completion and final certificate for payment.
8.23 Documents for Project Close-Out. Consultant shall cause all other architects, engineers and other consultants, as may be hired by Consultant, to file any and all required documentation with the City or other governmental authorities necessary to close out the Project.
Consultant shall assist the City in obtaining such documentation from all other architects, engineers, or other consultants.
9. AS-BUILT DRAWINGS.
During the as-built drawings phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
9.1 As-Built Drawings and Specifications. Not later than thirty (30) days after substantial completion of the Project, before receipt of final payment, Consultant shall review and forward the Final Working Drawings and Specifications, indicating on them all changes made by change orders or otherwise pursuant to the Construction Documents, as well as all information called for on the specifications, thus producing an “as-built” set of Final Working Drawings and Specifications (“As-Built Drawings and Specifications”). The As-Built Drawings and Specifications shall show, among other things, the location of all concealed pipe, buried conduit runs and other similar elements within the completed Project. Consultant shall personally review and certify that the As-Built Drawings and Specifications are a correct representation of the information supplied to Consultant by any inspectors and the contractor, and shall obtain certifications from any inspectors and the contractor that the drawings are correct.
9.2 Approval. Once City provides Consultant with specific written approval of the AsBuilt Drawings and Specifications, Consultant shall forward to City the complete set of original AsBuilt Drawings and Specifications or a complete set of reproducible duplicate As-Built Drawings and Specifications. The tracing shall be of such quality that clear and legible prints maybe made without appreciable and objectionable loss of detail.
9.3 Documents for Final Payment. Prior to the receipt of Consultant’s final payment, Consultant shall forward to City all of the following: (1) one clear and legible set of reproductions of the computations; (2) the original copy of the specifications; (3) the As-Built Drawings and Specifications as required herein; and (4) Consultant’s Certificate of Completion.
10. WARRANTY PERIOD.
During the warranty period phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
615
BB&K (2023)
46700.00100\40935196.1
Exhibit A-9
10.1 Advice. Consultant shall provide advice to City on apparent deficiencies in the Project during any applicable warranty periods for the Project. 616
BB&K (2023)
46700.00100\40935196.1
Exhibit B-1
EXHIBIT “B”
FEE AND PHASING/FUNDING SCHEDULES
1. FEE SCHEDULE.
Consultant will invoice City on a monthly cycle based on the following fee schedule.
Consultant will include with each invoice a detailed progress report that indicates the amount of budget spent on each phase and the total amount spent against the Total Compensation.
Consultant will inform City regarding any out-of-scope work being performed by Consultant for which Consultant intends to seek compensation from City.
2. PHASING/FUNDING SCHEDULE.
Progress payments towards Total Compensation shall never exceed the following percentages of Total Compensation as of the phase indicated:
617
(BB&K 2020)
46700.00100\33865500.1
618
BB&K (2023)
46700.00100\40935196.1
-1-
CITY OF ONTARIO
DESIGN SERVICES AGREEMENT
1. PARTIES AND DATE.
This Agreement is made and entered into as of , by and between the City of Ontario, a municipal corporation organized and operating under the laws of the State of California with its principal place of business at 303 East “B” Street, Ontario, California 91764- 4196, County of San Bernardino, State of California (“City”), and KWWA Architect, a corporation with its principal place of business at 9650 Telstar Ave., Unit A-119 El Monte, CA 91731 (hereinafter referred to as “Consultant”). City and Consultant are sometimes individually referred to herein as “Party” and collectively as “Parties.”
2. RECITALS.
2.1 City. City is a municipal corporation organized under the laws of the State of California, with power to contract for services necessary to achieve its purpose.
2.2 Consultant. Consultant desires to perform and assume responsibility for the provision of certain professional architectural design services requiredby the City on the terms and conditions set forth in this Agreement. Consultant warrants that it isfully licensed, qualified, and willing to perform the services required by this Agreement; provided, however, that if Consultant is a corporation or other organization, the Project Consultant designated pursuant to Section 3.2, and not the Consultant itself, shall be fully licensed to practiceas an architect in the State of California.
2.3 Project. City desires to engage Consultant to render such services for the On-Call Retail Architect Design Services ("Project") as set forth in this Agreement.
3. TERMS
3.1 Employment of Consultant.
3.1.1 Scope of Services. Consultant promises and agrees to furnish to City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the professional architectural and related services necessary for the full and adequate completion of the Project consistent with the provisions of this Agreement 619
BB&K (2023)
46700.00100\40935196.1
-2-
(hereinafter referred to as “Services”). The Services are more particularly described throughout this Agreement, including Exhibit “A” attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordancewith, this Agreement, any exhibits attached hereto and incorporated herein by reference, and allapplicable local, state and federal laws, rules and regulations. All Services performed by Consultant shall be subject to the sole and discretionary approval of the City, which approval shallnot be unreasonably withheld.
3.1.2 Term. The term of this Agreement shall be from July 16,2024 to July 16,2027, The City shall have the unilateral option, at its sole discretion, to renew this Agreement automatically for no more than two additional one-year terms unless earlier terminated as provided herein. Consultant shall complete the Services within the term of agreement and shall meet any other established scheduled and deadlines.
3.2 Project Consultant; Key Personnel.
3.2.1 Retail Architect. Consultant shall name a specific individual to act as Project Consultant, subject to the approval of City. Consultanthereby designates Wing Wong (License No. #C39010) to act as the Retail Architect for the Project. The Architect shall: (1) maintain oversight of the Services; (2) have full authority to represent and act on behalf of the Consultant for all purposes under thisAgreement; (3) supervise and direct the Services using his or her best skill and attention; (4) be responsible for the means, methods, techniques, sequences and procedures used for theServices; (5) adequately coordinate all portions of the Services; and (6) act as principal contact with y and all contractors, consultants, engineers and inspectors on the Project.
Any change in the Retail Architect shall be subject to the City’s prior written approval, which approval shall not be unreasonably withheld. The new Retail Architect shall be of at least equal competence as the prior Retail Architect. In the event that City and Consultant cannotagree as to the substitution of a new Retail Architect. City shall be entitled to terminate this Agreement for cause.
3.2.2 Key Personnel. In addition to the Retail Architect, Consultant has represented to the City that certain additional key personnel, engineers and consultants will perform the Services under this Agreement. Should one or more of such personnel, engineers or consultants become unavailable, Consultant may substitute others of atleast equal competence upon written approval of the City. In the event that City and Consultant cannot agree as to the substitution of key personnel, engineers or consultants, City shall be entitled to terminate this Agreement for cause. The key additional personnel, engineers and consultants for performance of this Agreement are as follows: Wing Wong, Principal
3.3 Hiring of Consultants and Personnel.
3.3.1 Right to Hire or Employ. Consultant shall have the option, unless City objects in writing after notice, to employ at its expense architects, engineers, experts or other consultants qualified and licensed to render services in connection with the planning and/or administration of the Project, and to delegate to them such duties as Consultant may delegate without relieving Consultant from administrative or other responsibility under this Agreement.
Consultant shall be responsible for the coordination and cooperation of Consultant’s architects, engineers, experts or other consultants. All consultants, including changes in consultants, shall be subject to approval by City in its sole and reasonable discretion. Consultant shall notify City of the identity of all consultants at least fourteen (14) days prior to their commencement of work to allow City to review their qualifications and approve to their participation on the Project in its sole and reasonable discretion.
620
BB&K (2023)
46700.00100\40935196.1
-3-
3.3.2 Qualification and License. All architects, engineers, experts and other consultants retained by Consultant in performance of this Agreement shall be qualified to perform the Services assigned to them, and shall be licensed to practice in their respective professions, where required by law.
3.3.3 Standards and Insurance. All architects, engineers, experts and other consultants hired by Consultant shall be required to meet all of the same standards and insurance requirements set forth in this Agreement, unless other standards or requirements are approved by the City in writing. Unless changes are approved in writing by the City, Consultant’s agreements with its consultants shall contain a provision making them subject to all provisions stipulated in this Agreement.
3.3.4 Assignments or Staff Changes. Consultant shall promptly obtain written City approval of any assignment, reassignment or replacement of such architects, engineers, experts and consultants, or of other staff changes of key personnel working on the Project. As provided in the Agreement, any changes in Consultant’s consultants and key personnel shall be subject to approval by City.
3.3.5 Draftsman and Clerical Support. Draftsmen and clerical personnel shall be retained by Consultant at Consultant’s sole expense.
3.4 Standard of Care.
3.4.1 Standard of Care. Consultant shall perform all Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals qualified to perform the Services in the same discipline in the State of California, and shall be responsible to City for damages sustained by the City and delays to the Project as specified in the indemnification provision of this Agreement. Without limiting the foregoing, Consultant shall be fully responsible to the City for any increased costs incurred by the City as a result of any such delays in the design or construction of the Project. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services. Consultant warrants and represents that all of its employees, architects, engineers, experts and other consultants shall have sufficient skill and experience to perform the Services assigned to them. Finally, Consultant represents that it, its employees, architects, engineers, experts and other consultants have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services assigned to or rendered by them and that such licenses and approvals shall be maintained throughout the term of this Agreement. As provided for in the indemnification provisions of this Agreement, Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant’s failure to comply with the standard of care provided for herein.
3.4.2 Performance of Employees. Any employee or consultant who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee or consultant who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed from the Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.
621
BB&K (2023)
46700.00100\40935196.1
-4-
3.5 Laws and Regulations.
3.5.1 Knowledge and Compliance. Consultant shall keep itself fully informed of and in compliance with all applicable local, state and federal laws, rules and regulations in any manner affecting the performance of the Services or the Project, and shall give all notices required of the Consultant by law. Consultant shall be liable, pursuant to the standard of care and indemnification provisions of this Agreement, for all violations of such laws and regulations in connection with its Services. Consultant shall defend, indemnify and hold City, its officials, officers, employees and agents free and harmless, pursuant to the indemnification provisions of this Agreement, from any claim or liability arising out of any failure or alleged failure to comply with such laws, rules or regulations.
3.5.2 Drawings and Specifications. Consultant shall cause all drawings and specifications to conform to any applicable requirements of federal, state and local laws, rules and regulations, including the Uniform Building Code, in effect as of the time the drawings and specifications are prepared or revised during the latest phase of the Services described in Exhibit “A” attached hereto. Any significant revisions made necessary by changes in such laws, rules and regulations after this time may be compensated as Additional Services which were not knownor reasonably should not have been known by Consultant. Consultant shall cause the necessary copies of such drawings and specifications to be filed with any governmental bodies with approval jurisdiction over the Project, in accordance with the Services described in Exhibit “A” attached hereto. For the preparation of all such drawings and specifications, the Consultant shall use Computer Aided Design Drafting (“CADD”) (e.g., AutoCAD) or other technology acceptable to the Consultant and City.
3.5.3 Americans with Disabilities Act. Consultant will use its best professional efforts to interpret all applicable federal, state and local laws, rules and regulations with respect to access, including those of the Americans with Disabilities Act (“ADA”). Consultant shall inform City of the existence of inconsistencies of which it is aware or reasonably should be aware between federal and state accessibility laws, rules and regulations, as well as any other issues which are subject to conflicting interpretations of the law, and shall provide the City with its interpretation of such inconsistencies and conflicting interpretations. Unless Consultant brings such inconsistencies and conflicting interpretations to the attention of the City and requests City’s direction on how to proceed, the Consultant’s interpretation of such inconsistencies and conflicting interpretations shall be the sole responsibility and liability of Consultant, and the Consultant shall correct all plans, specifications and other documents prepared for the Project at no additional cost if its interpretations are shown to be incorrect. In the event that the Consultant request’s City’s direction on how to proceed with respect to any inconsistent and/or conflicting interpretation, the Consultant shall be responsible to the City only pursuant to the indemnification provisions of this Agreement.
3.5.4 Permits, Approvals and Authorizations. Consultant shall provide City with a list of all permits, approvals or other authorizations required for the Project from all federal, stateor local governmental bodies with approval jurisdiction over the Project. Consultant shall then assist the City in obtaining all such permits, approvals and other authorizations. The costs of such permits, approvals and other authorizations shall be paid by the City.
3.5.5 Water Quality Management and Compliance. Consultant shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance 622
BB&K (2023)
46700.00100\40935196.1
-5-
of the Services including, without limitation, all applicable provisions of the City’s ordinances regulating water quality and storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251 et seq.); the California Porter-Cologne Water Quality Control Act (Cal Water Code §§ 13000- 14950); and any and all regulations, policies, or permits issued pursuant to any such authority.
Consultant shall additionally comply with the lawful requirements of the City, and any other municipality, drainage district, or other local agency with jurisdiction over the location where the Services are to be conducted, regulating water quality and storm water discharges. Failure to comply with laws, regulations, and ordinances listed in this Section is a violation of federal and state law.
3.6 Independent Contractor.
3.6.1 Control and Payment of Subordinates. City retains Consultant on an independent contractor basis and Consultant is not an employee of City. Consultant is not an employee for state tax, federal tax or any other purpose, and is not entitled to the rights or benefits afforded to City’s employees. Any additional personnel performing the Services under this Agreement on behalf of Consultant shall also not be employees of City, and shall at all times be under Consultant’s exclusive direction and control. Consultant shall pay all wages, salaries, and other amounts due such personnel in connection with their performance of Services under this Agreement and as required by law. Consultant shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers’ compensation insurance.
3.7 Schedule of Services.
3.7.1 Consultant Services. Consultant shall fully and adequately complete the Services described in this Agreement and in Exhibit “A” attached hereto and incorporated herein by reference.
3.7.2 Timely Performance Standard. Consultant shall perform all Services hereunder as expeditiously as is consistent with professional skill and care, as well as the orderly progress of the Project work so as not to be the cause, in whole or in part, of delays in the completion of the Project or in the achievement of any Project milestones, as provided herein.
Specifically, Consultant shall perform its Services so as to allow for the full and adequate completion of the Project within the time required by the City and within any completion schedules adopted for the Project. Consultant agrees to coordinate with City’s staff, contractors and consultants in the performance of the Services, and shall be available to City’s staff, contractors and consultants at all reasonable times.
3.7.3 Performance Schedule. Consultant shall prepare an estimated time schedule for the performance of Consultant’s Services, to be adjusted as the Project proceeds.
Such schedule shall be subject to the City’s review and approval, which approval shall not be unreasonably withheld, and shall include allowances for periods of time required for City’s review and approval of submissions, and for approvals of authorities having jurisdiction over Project approval and funding. If City and Consultant cannot mutually agree on a performance schedule, City shall have the authority to immediately terminate this Agreement. The schedule shall not be 623
BB&K (2023)
46700.00100\40935196.1
-6-
exceeded by Consultant without the prior written approval of City. If the Consultant’s Services are not completed within the time provided by the agreed upon performance schedule, or any milestones established therein, it is understood, acknowledged and agreed that the City will suffer damage for which the Consultant will be responsible.
3.7.4 Excusable Delays. Any delays in Consultant’s work caused by the following may be added to the time for completion of any obligations of Consultant: (1) the actionsof City or its employees; (2) the actions of those in direct contractual relationship with City; (3) theactions of any governmental agency having jurisdiction over the Project; (4) the actions of any parties not within the reasonable control of the Consultant; and (5) any Force Majeure Event (asdefined herein) or other unforeseen occurrence not due to any fault or negligence on the part of Consultant. Neither the City nor the Consultant shall be liable for damages, liquidated or otherwise, to the other on account of such delays.
3.7.5 Force Majeure Events. Neither City nor Consultant shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the non-performing Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Consultant and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the Services and Agreement. Should a Force Majeure Event occur, the nonperforming Party shall, within fifteen (15) calendar days of the beginning of an Force Majeure Event, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events shall not entitle Consultant to any additional compensation. Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement.
3.7.6 Request for Excusable Delay Credit. The Consultant shall, within fifteen (15) calendar days of the beginning of any excusable delay, notify the City in writing of the causes of delay (unless City grants in writing a further period of time to file such notice prior to the date of final payment under the Agreement). City will then ascertain the facts and the extent of the delay, and grant an extension of time for completing the Services when, in its sole judgment, the findings of fact justify such an extension. The City’s findings of fact thereon shall be final and conclusive on the Parties. Extensions of time shall apply only to that portion of the Services affected by the delay and shall not apply to other portions of the Services not so affected. The sole remedy of Consultant for extensions of time shall be an extension of the performance time at no cost to the City. If Additional Services are required as a result of an excusable delay, the Parties shall mutually agree thereto pursuant to the Additional Services provision of this Agreement. Should Consultant make an application for an extension of time, Consultant shall submit evidence that the insurance policies required by this Agreement remain in effect during the requested additional period of time.
624
BB&K (2023)
46700.00100\40935196.1
-7-
3.8 Additional Services.
3.8.1 Request for Services. At City’s request, Consultant may be asked to perform services not otherwise included in this Agreement, not included within the basic services listed in Exhibit “A” attached hereto, and/or not customarily furnished in accordance with generally accepted architectural practice.
3.8.2 Definition. As used herein, “Additional Services” mean: (1) any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary for the Consultant to perform at the execution of this Agreement; or (2) any work listed as Additional Services in Exhibit “A” attached hereto. Consultant shall not perform, nor be compensated for, Additional Services without prior written authorization from City and without an agreement between the City and Consultant as to the compensation to be paid for such services. City shall pay Consultant for any approved Additional Services, pursuant to the compensation provisions herein, so long as such services are not made necessary through the fault of Consultant pursuant to the indemnification provision of this Agreement.
3.8.3 Examples of Additional Services. Such Additional Services shall notinclude any redesign or revisions to drawings, specifications or other documents when such revisions are necessary in order to bring such documents into compliance with applicable laws, rules, regulations or codes of which Consultant was aware or should have been aware pursuantto the laws and regulations provision of this Agreement above. Such Additional Services may include, but shall not be limited to:
(a) Separately Bid Portions of Project. Plan preparation and/or administration of work on portions of the Project separately bid. (b) Furniture and Interior Design. Assistance to City, if requested, for the selection of moveable furniture, equipment or articles which are not included in the Construction Documents.
(c) Fault of Contractor. Services caused by delinquency, default or insolvency of contractor, or by major defects in the work of the contractor, provided that any such services made necessary by the failure of Consultant to detect and report such matters when it reasonably should have done so shall not be compensated. (d) Inconsistent Approvals or Instructions. Revisions in drawings, specifications or other documents when such revisions are inconsistent with written approvals or instructions previously given and are due to causes beyond the control of Consultant. (e) Legal Proceedings. Serving as an expert witness on City's behalf or attending legal proceedings to which the Consultant is not a party. (f) Damage Repair. Supervision of repair of damages to any structure. (g) Extra Environmental Services. Additional work required for environmental conditions (e.g. asbestos or site conditions) not already contemplated within the Consultant's services for the Project.
3.9 City Responsibilities. City’s responsibilities shall include the following:
625
BB&K (2023)
46700.00100\40935196.1
-8-
3.9.1 Data and Information. City shall make available to Consultant all necessary data and information concerning the purpose and requirements of the Project, including scheduling and budget limitations, objectives, constraints and criteria. As part of the budget limitation information, the City shall provide the Consultant with a preliminary construction budget (“City’s Preliminary Construction Budget”).
3.9.2 Project Survey. If required pursuant to the scope of the Project and if requested by Consultant, City shall furnish Consultant with, or direct Consultant to procure at City’s expense, a survey of the Project site prepared by a registered surveyor or civil engineer, any other record documents which shall indicate existing structures, land features, improvements, sewer, water, gas, electrical and utility lines, topographical information and boundary dimensions of the site, and any other such pertinent information.
3.9.3 Bid Phase. Distribute Construction Documents to bidders and conduct the opening and review of bids for the Project.
3.9.4 Testing. Retain consultant(s) to conduct chemical, mechanical, soils, geological or other tests required for proper design of the Project, and furnish such surveys, borings, test pits, and other tests as may be necessary to reveal conditions of the site which must be known to determine soil condition or to ensure the proper development of the required drawings and specifications.
3.9.5 Required Inspections and Tests. Retain consultant(s) to conduct materials testing and inspection or environmental/hazardous materials testing and inspection pursuant to any applicable laws, rules or regulations.
3.9.6 Fees of Reviewing or Licensing Agencies. Directly pay or reimburse the payment of all fees required by any reviewing or licensing agency, or other agency having approval jurisdiction over the Project.
3.9.7 City’s Representative. The City hereby designates the City Manager, or his or her designee, to act as its representative for the performance of this Agreement (“City’s Representative”). City’s Representative shall have the power to act on behalf of the City for all purposes under this Contract. The City Manager hereby designates Tito Haes , Executive Director Public Works, or his or her designee, as the City’s contact for the implementation of the Services hereunder. Contractor shall not accept direction or orders from any person other than the City’s Representative or his or her designee.
3.9.8 Review and Approved Documents. Review all documents submitted by Consultant, including change orders and other matters requiring approval by the City Council or other officials. City shall advise Consultant of decisions pertaining to such documents within a reasonable time after submission, so as not to cause unreasonable delay as provided in the excusable delay provisions of this Agreement above.
3.10 Compensation.
3.10.1 Consultant’s Compensation for Basic Services. City shall pay to Consultant, for the performance of all Services rendered under this Agreement, the total not to exceed amount of One Hundred Fifty Thousand Dollars ($150,000) (“Total Compensation”).
This Total Compensation amount shall be based upon, and may be adjusted according to, the fee schedule and related terms and conditions attached hereto as Exhibit “B” and incorporated herein by reference. The Total Compensation, as may be adjusted upon mutual agreement, shall 626
BB&K (2023)
46700.00100\40935196.1
-9-
constitute complete and adequate payment for Services under thisAgreement.
3.10.2 Payment for Additional Services. At any time during the term of this Agreement, City may request that Consultant perform Additional Services. As used herein, Additional Services means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement. Any additional work in excess of this amount must be approved by the City. If authorized, such Additional Services will be compensated at the rates and in the manner set forth in Exhibit “B” attached hereto and incorporated herein by reference, unless a flat rate or some other form of compensation is mutually agreed upon by the Parties. IfCity requires Consultant to hire consultants to perform any Additional Services, Consultant shall be compensated therefore at the rates and in the manner set forth in Exhibit “B” attached heretoand incorporated herein by reference, unless a flat rate or some other form of compensation is mutually agreed upon by the Parties. City shall have the authority to review and approve the rates of any such consultants. In addition, Consultant shall be reimbursed for any expenses incurred by such consultants pursuant to the terms and conditions of Section 3.10.3.
3.10.3 Reimbursable Expenses. Reimbursable expenses are in addition to compensation for the Services and Additional Services. Consultant shall not be reimbursed for any expenses unless authorized in writing by City, which approval may be evidenced by inclusion in Exhibit “C” attached hereto. Such reimbursable expenses shall include only those expenses which are reasonably and necessarily incurred by Consultant in the interest of the Project.
Consultant shall be required to acquire prior written consent in order to obtain reimbursement for the following: (1) extraordinary transportation expenses incurred in connection with the Project; (2) out-of-town travel expenses incurred in connection with the Project; (3) fees paid for securing approval of authorities having jurisdiction over the Project; (4) bid document duplication costs in excess of $1,000; and (5) other costs, fees and expenses in excess of $1,000.
3.10.4 Payment to Consultant. Consultant’s compensation and reimbursable expenses shall be paid by City to Consultant no more often than monthly. Such periodic payments shall be made based upon the percentage of work completed, and in accordance with the phasing and funding schedule provided in Exhibit “B” and the compensation rates indicated in Exhibit “B” attached hereto and incorporated herein by reference. In order to receive payment, Consultant shall present to City an itemized statement which indicates Services performed, percentage of Services completed, method for computing the amount payable, and the amount to be paid. The statement shall describe the amount of Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement, as well as those expenses for which reimbursement is requested for that statement period. The amount paid to Consultant shall never exceed the percentage amounts authorized by the phasing and funding schedule located in Exhibit “B” attached hereto. City shall, within thirty (30) days of receiving such statement, review the statement and pay all approved charges thereon pursuant to the provisions of Civil Code Section 3320. Disputed amounts shall be resolved by the Parties in a mutually agreeable manner.
Payments made for Additional Services shall be made in installments, not more often than monthly, proportionate to the degree of completion of such services or in such other manner as the Parties shall specify when such services are agreed upon, and in accordance with any authorized fee or rate schedule. In order to receive payment, Consultant shall present to City an itemized statement which indicates the Additional Services performed, percentage of Additional Services completed, method for computing the amount payable, and the amount to be paid. The statement shall describe the amount of Additional Services provided since the initial 627
BB&K (2023)
46700.00100\40935196.1
-10-
commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement. City shall, within thirty (30) days of receiving such statement, review the statement and pay all approved charges thereon pursuant to the provisions of Civil Code Section 3320. Disputed amounts shall be resolved by the Parties in a mutually agreeable manner.
Upon cancellation or termination of this Agreement, Consultant shall be compensated as set forth in the termination provision herein.
3.10.5 Withholding Payment to Consultant. The City may withhold payment, in whole or in part, to the extent reasonably necessary to protect the City from claims, demands, causes of action, costs, expenses, liabilities, losses, damages, or injuries of any kind to the extent arising out of or caused by the negligence, recklessness, or willful misconduct protected under the indemnification provisions of this Agreement. Failure by City to deduct any sums from a progress payment shall not constitute a waiver of the City’s right to such sums. The City may keep any moneys which would otherwise be payable at any time hereunder and apply the same,or so much as may be necessary therefor, to the payment of any expenses, losses, or damagesas determined by the City, incurred by the City for which Consultant is liable under the Agreementor state law. Payments to the Consultant for compensation and reimbursable expenses due shallnot be contingent on the construction, completion or ultimate success of the Project. Payment tothe Consultant shall not be withheld, postponed, or made contingent upon receipt by the City of offsetting reimbursement or credit from Parties not within the Consultant’s reasonable control.
3.10.6 Prevailing Wages. Consultant is aware of the requirements of California Labor Code Sections 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., (“Prevailing Wage Laws”), which require the payment of prevailing wage rates and the performance of other requirements on certain “public works” and “maintenance” projects. If the Services are being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and if the total compensation is $1,000 or more, Consultant agrees to fully complywith and to require its consultants to fully comply with such Prevailing Wage Laws. City shall provide Consultant with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Consultant shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services available to interested parties upon request, and shall post copies at the Consultant’s principal place of business and at the Project site. It shall be mandatory upon the Consultant and all subconsultants to comply with all California Labor Code provisions, which include but are not limited to prevailing wages (Labor Code Sections 1771, 1774 and 1775), employment of apprentices (Labor Code Section 1777.5), certified payroll records (Labor Code Sections 1771.4and 1776), hours of labor (Labor Code Sections 1813 and 1815) and debarment of contractors and subcontractors (Labor Code Section 1777.1). The requirement to submit certified payroll records directly to the Labor Commissioner under Labor Code section 1771.4 shall not apply to work performed on a public works project that is exempt pursuant to the small project exemption specified in Labor Code Section 1771.4. Consultant shall defend, indemnify and hold the City, itselected officials, officers, employees and agents free and harmless from any claims, liabilities, costs, penalties or interest arising out of any failure or alleged failure of the Consultant or its consultants to comply with the Prevailing Wage Laws. (a) Registration/DIR Compliance. If the Services are being performed as part of an applicable “public works project” of over $25,000 when the project is for construction, alteration, demolition, installation, or repair work, or a public works project of over $15,000 when the project is for maintenance work, in addition to the foregoing, then pursuant to Labor Code sections 1725.5 and 1771.1, the Consultant and all subconsultants performing such Services 628
BB&K (2023)
46700.00100\40935196.1
-11-
must be registered with the Department of Industrial Relations (“DIR”). Consultant shall maintain registration for the duration of the Project and require the same of any subconsultants. This project may also be subject to compliance monitoring and enforcement by the DIR. It shall be Consultant’s sole responsibility to comply with all applicable registration and labor compliance requirements, including the submission of payroll records directly to the DIR. Any stop orders issued by the Department of Industrial Relations against Consultant or any subconsultant that affect Consultant’s performance of services, including any delay, shall be Consultant’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Consultant caused delay and shall not be compensable by the City. Consultant shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the Department of Industrial Relations against Consultant or any subconsultant.
3.11 Notice to Proceed.
Consultant shall not proceed with performance of any Services under this Agreement unless and until the City provides a written notice to proceed.
3.12 Termination, Suspension and Abandonment.
3.12.1 Grounds for Termination; Consultant’s Termination for Cause. City hereby reserves the right to suspend or abandon, at any time and for any reason, all or any portion of the Project and the construction work thereon, or to terminate this Agreement at any time with or without cause. Consultant shall be provided with at least seven (7) days advanced written notice of such suspension, abandonment or termination. In the event of such suspension, abandonment or termination, Consultant shall be paid for Services and reimbursable expenses rendered up to the date of such suspension, abandonment or termination, pursuant to the schedule of payments provided for in this Agreement, less any claims against or damages suffered by City as a result of the default, if any, by Consultant. Consultant hereby expressly waives any and all claims for damages or compensation arising under this Agreement, except as set forth herein, in the event of such suspension, abandonment or termination. Consultant may terminate this Agreement for substantial breach of performance by the City such as failure to make payment to Consultant as provided in this Agreement.
3.12.2 City’s Suspension of Work. If Consultant’s Services are suspended by City, City may require Consultant to resume such Services within ninety (90) days after written notice from City. When the Project is resumed, the Total Compensation and schedule of Services shall be equitably adjusted upon mutual agreement of the City and Consultant.
3.12.3 Documents and Other Data. Upon suspension, abandonment or termination, Consultant shall provide to City all preliminary studies, sketches, working drawings, specifications, computations, and all other Project Documents, as defined below, to which City would have been entitled at the completion of Consultant’s Services under this Agreement. Upon payment of the amount required to be paid to Consultant pursuant to the termination provisions of this Agreement, City shall have the rights, as provided in this Agreement hereinafter, to use such Project Documents prepared by or on behalf of Consultant under this Agreement. Consultant shall make such documents available to City upon request and without additional compensation other than as may be approved as a reimbursable expense.
3.12.4 Employment of other Consultants. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such 629
BB&K (2023)
46700.00100\40935196.1
-12-
manner as it may determine appropriate, services similar to those terminated.
3.13 Ownership and Use of Documents; Confidentiality.
3.13.1 Ownership. All plans, specifications, original or reproducibletransparencies of working drawings and master plans, preliminary sketches, architectural presentation drawings, structural computations, estimates and any other documents prepared pursuant to this Agreement, including, but not limited to, any other works of authorship fixed in any tangible medium of expression such as writings, physical drawings and data magnetically orotherwise recorded on computer diskettes (hereinafter referred to as the “Project Documents”) shall be and remain the property of City. Although the official copyright in all Project Documentsshall remain with the Consultant or other applicable subcontractors or consultants, the Project Documents shall be the property of City whether or not the work for which they were made is executed or completed. Within thirty (30) calendar days following completion of the Project, Consultant shall provide to City copies of all Project Documents required by City. In addition, Consultant shall retain copies of all Project Documents on file for a minimum of fifteen (15) years following completion of the Project, and shall make copies available to City upon the payment ofreasonable duplication costs. Before destroying the Project Documents following this retention period, Consultant shall make a reasonable effort to notify City and provide City with the opportunity to obtain the documents.
3.13.2 Right to Use. Consultant grants to City the right to use and reuse all or part of the Project Documents, at City’s sole discretion and with no additional compensation to Consultant, for the following purposes:
(a) The construction of all or part of this Project.
(b) The repair, renovation, modernization, replacement, reconstruction or expansion of this Project at any time;
(c) The construction of another project by or on behalf of the City for its ownership and use;
City is not bound by this Agreement to employ the services of Consultant in the event such documents are used or reused for these purposes. City shall be able to use or reuse the Project Documents for these purposes without risk of liability to the Consultant or third parties with respect to the condition of the Project Documents, and the use or reuse of the Project Documents for these purposes shall not be construed or interpreted to waive or limit City’s right to recover for latent defects or for errors or omissions of the Consultant.
Any use or reuse by City of the Project Documents on any project other than this Project without employing the services of Consultant shall be at City’s own risk with respect to third parties. If City uses or reuses the Project Documents on any project other than this Project, it shall remove the Consultant’s seal from the Project Documents and hold harmless Consultant and its officers, directors, agents and employees from claims arising out of the negligent use or re-use of the Project Documents on such other project.
3.13.3 License. This Agreement creates a non-exclusive and perpetual license for City to copy, use, modify or reuse any and all Project Documents and any intellectual property rights therein. Consultant shall require any and all subcontractors and consultants to agree in writing that City is granted a non-exclusive and perpetual license for the work of such 630
BB&K (2023)
46700.00100\40935196.1
-13-
subcontractors or consultants performed pursuant to this Agreement.
3.13.4 Right to License. Consultant represents and warrants that Consultant has the legal right to license any and all copyrights, designs and other intellectual property embodied in the Project Documents that Consultant prepares or causes to be prepared pursuant to this Agreement. Consultant shall indemnify and hold City harmless pursuant to the indemnification provisions of this Agreement for any breach of this Section. Consultant makes no such representation and warranty in regard to previously prepared designs, plans, specifications, studies, drawings, estimates or other documents that were prepared by design professionals other than Consultant and provided to Consultant by City.
3.13.5 Confidentiality. All Project Documents, either created by or provided to Consultant in connection with the performance of this Agreement, shall be held confidential by Consultant to the extent they are not subject to disclosure pursuant to the Public Records Act. All Project Documents shall not, without the written consent of City, be used or reproduced by Consultant for any purposes other than the performance of the Services. Consultant shall not disclose, cause or facilitate the disclosure of the Project Documents to any person or entity not connected with the performance of the Services or the Project. Nothing furnished to Consultant which is otherwise known to Consultant or is generally known, or has become known, to the related industry shall be deemed confidential. Consultant shall not use City’s name or insignia, photographs of the Project, or any publicity pertaining to the Services or the Project in any magazine, trade paper, newspaper, television or radio production or other similar medium without the written consent of City.
3.14 Indemnification.
3.14.1 To the fullest extent permitted by law, Consultant shall defend (with counsel of City’s choosing), indemnify and hold the City, its officials, officers, employees, volunteers, and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Consultant, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Consultant’s Services, the Project or this Agreement, including without limitation the payment of all damages, expert witness fees and attorney’s fees and other related costs and expenses except such loss or damage caused by the sole negligence or willful misconduct of the City. Consultant's obligation to indemnify shall survive expiration or termination of this Agreement and shall not be restricted to insurance proceeds, if any, received by Consultant, the City, its officials, officers, employees, agents, or volunteers.
3.14.2 If Consultant’s obligation to defend, indemnify, and/or hold harmless arises out of Consultant’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Consultant’s indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Consultant, and, upon Consultant obtaining a final adjudication by a court of competent jurisdiction, Consultant’s liability for such claim, including the cost to defend, shall not exceed the Consultant’s proportionate percentage of fault.
3.15 Insurance. Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this 631
BB&K (2023)
46700.00100\40935196.1
-14-
Section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurancerequired under this section.
3.15.1 Types of Insurance Required. As a condition precedent to the effectiveness of this Agreement for work to be performed hereunder, and without limiting the indemnity provisions of the Agreement, Consultant shall, at its expense, procure and maintain infull force and effect for the duration of the Agreement the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Consultant agrees to amend, supplement or endorse the policies to do so.
3.15.2 Additional Insured. The City of Ontario, its officials, officers, employees, agents, and volunteers shall be named as additional insureds on Consultant’s and its subconsultants’ policies of commercial general liability and automobile liability insurance using the endorsements and forms specified herein or exact equivalents.
3.15.3 Commercial General Liability
(a) The Consultant shall take out and maintain, during the performance of all work under this Agreement, in amounts not less than specified herein, Commercial General Liability Insurance, in a form and with insurance companies acceptable to the City. (b) Coverage for Commercial General Liability insurance shall be at least as broad as the following: Insurance Services Office Commercial General Liability coverage (Occurrence Form CG 00 01) or exact equivalent. Commercial General Liability Insurance must include coverage for the following:
(i) Bodily Injury and Property Damage
(ii) Personal Injury/Advertising Injury
(iii) Premises/Operations Liability
(iv) Products/Completed Operations Liability
(v) Aggregate Limits that Apply per Project
(vi) Explosion, Collapse and Underground (UCX) exclusion deleted
(vii) Contractual Liability with respect to this Contract (viii) Broad Form Property Damage
(ix) Independent Consultants Coverage
(c) The policy shall contain no endorsements or provisions limiting coverage for (1) contractual liability; (2) cross liability exclusion for claims or suits by one insured against another; (3) products/completed operations liability; or (4) contain any other exclusion contrary to the Agreement.
632
BB&K (2023)
46700.00100\40935196.1
-15-
(d) The policy shall give City, the City Council and each member of the City Council, its officers, employees, agents and City designated volunteers additional insured status using ISO endorsement forms CG 20 10 10 01 and 20 37 10 01, or endorsements providing the exact same coverage.
(e) The general liability program may utilize either deductibles or provide coverage excess of a self-insured retention, subject to written approval by the City, and provided that such deductibles shall not apply to the City as an additional insured.
3.15.4 Automobile Liability
(a) At all times during the performance of the work under this Agreement, the Consultant shall maintain Automobile Liability Insurance for bodily injury and property damage including coverage for owned, non-owned and hired vehicles, in a form and with insurance companies acceptable to the City.
(b) Coverage for automobile liability insurance shall be at least as broad as Insurance Services Office Form Number CA 00 01 covering automobile liability (Coverage Symbol 1, any auto).
(c) The policy shall give City, the City Council and each member of the City Council, its officers, employees, agents and City designated volunteers additional insured status.
(d) Subject to written approval by the City, the automobile liability program may utilize deductibles, provided that such deductibles shall not apply to the City as an additional insured, but not a self-insured retention.
3.15.5 Workers’ Compensation/Employer’s Liability
(a) Consultant certifies that he/she is aware of the provisions of Section 3700 of the California Labor Code which requires every employer to be insured against liability for workers’ compensation or to undertake self-insurance in accordance with the provisions of that code, and he/she will comply with such provisions before commencing work under this Agreement.
(b) To the extent Consultant has employees at any time during the term of this Agreement, at all times during the performance of the work under this Agreement, the Consultant shall maintain full compensation insurance for all persons employed directly by him/her to carry out the work contemplated under this Agreement, all in accordance with the “Workers’ Compensation and Insurance Act,” Division IV of the Labor Code of the State of California and any acts amendatory thereof, and Employer’s Liability Coverage in amounts indicated herein. Consultant shall require all subconsultants to obtain and maintain, for the period required by this Agreement, workers’ compensation coverage of the same type and limits as specified in this Section.
3.15.6 Professional Liability (Errors and Omissions)
(a) At all times during the performance of the work under this Agreement the Consultant shall maintain professional liability or Errors and Omissions insurance appropriate to its profession, in a form and with insurance companies acceptable to the City and 633
BB&K (2023)
46700.00100\40935196.1
-16-
in an amount indicated herein. This insurance shall be written on a policy form coverage specifically designed to protect against acts, errors or omissions of the Consultant. “Covered Professional Services” as designated in the policy must specifically include work performed under this Agreement. The policy must “pay on behalf of” the insured and must include a provision establishing the insurer's duty to defend.
3.15.7 Minimum Policy Limits Required
(a) The following insurance limits are required for the Agreement:
Coverage Combined Single Limit
Commercial General Liability $2,000,000 per occurrence/ $4,000,000 aggregate for bodily injury, personal
injury, and property damage
Automobile Liability $2,000,000 per occurrence for bodily injury and property damage
Employer’s Liability $1,000,000 per occurrence
Professional Liability $2,000,000 per claim and aggregate (errors and omissions)
(b) Defense costs shall be payable in addition to the limits. (c) Requirements of specific coverage or limits contained in this Section are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance. Any available coverage shall be provided to the parties required to be named as Additional Insured pursuant to this Agreement.
3.15.8 Evidence Required
(a) Prior to execution of the Agreement, the Consultant shall file with the City evidence of insurance from an insurer or insurers certifying to the coverage of all insurance required herein. Such evidence shall include original copies of the ISO CG 00 01 (or insurer’s equivalent) signed by the insurer’s representative and Certificate of Insurance (Acord Form 25-S or equivalent), together with required endorsements. All evidence of insurance shall be signed by a properly authorized officer, agent, or qualified representative of the insurer and shall certify the names of the insured, any additional insureds, where appropriate, the type and amount of the insurance, the location and operations to which the insurance applies, and the expiration date of such insurance.
3.15.9 Policy Provisions Required
(a) Consultant shall provide the City at least thirty (30) days prior written notice of cancellation of any policy required by this Agreement, except that the Consultantshall provide at least ten (10) days prior written notice of cancellation of any such policy due to nonpayment of premium. If any of the required coverage is cancelled or expires during the termof this Agreement, the Consultant shall deliver renewal certificate(s) including the General Liability Additional Insured Endorsement to the City at least ten (10) days prior to the effective date of cancellation or expiration.
634
BB&K (2023)
46700.00100\40935196.1
-17-
(b) The Commercial General Liability Policy and Automobile Policy shall each contain a provision stating that Consultant’s policy is primary insurance and that any insurance, deductible, or self-insurance maintained by the City, its officials, officers, employees, agents, or volunteers shall not contribute with this primary insurance. Policies shall contain or be endorsed to contain such provisions.
(c) The retroactive date (if any) of each policy is to be no later than the effective date of this Agreement. Consultant shall maintain such coverage continuously for a period of at least three years after the completion of the work under this Agreement. Consultant shall purchase a one (1) year extended reporting period A) if the retroactive date is advanced past the effective date of this Agreement; B) if the policy is cancelled or not renewed; or C) if thepolicy is replaced by another claims-made policy with a retroactive date subsequent to the effective date of this Agreement.
(d) All required insurance coverages, except for the professional liability coverage, shall contain or be endorsed to waiver of subrogation in favor of the City, its officials, officers, employees, agents, and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these specifications to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants.
(e) The limits set forth herein shall apply separately to each insured against whom claims are made or suits are brought, except with respect to the limits of liability.
Further the limits set forth herein shall not be construed to relieve the Consultant from liability in excess of such coverage, nor shall it limit the Consultant’s indemnification obligations to the City and shall not preclude the City from taking such other actions available to the City under other provisions of the Agreement or law.
3.15.10 Qualifying Insurers
(a) All policies required shall be issued by acceptable insurance companies, as determined by the City, which satisfy the following minimum requirements: Each such policy shall be from a company or companies with a current A.M. Best's rating of no less than A:VII and admitted to transact in the business of insurance in the State of California, or otherwise allowed to place insurance through surplus line brokers under applicable provisions of the California Insurance Code or any federal law.
3.15.11 Additional Insurance Provisions
(a) The foregoing requirements as to the types and limits of insurance coverage to be maintained by Consultant, and any approval of said insurance by the City, is not intended to and shall not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Consultant pursuant to this Agreement, including but not limited to, the provisions concerning indemnification.
(b) If at any time during the life of the Agreement, any policy of insurance required under this Agreement does not comply with these specifications or is canceled and not replaced, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Consultant or City will withhold 635
BB&K (2023)
46700.00100\40935196.1
-18-
amounts sufficient to pay premium from Consultant payments. In the alternative, City may cancel this Agreement.
(c) The City may require the Consultant to provide complete copies of all insurance policies in effect for the duration of the Project. (d) Neither the City nor the City Council, nor any member of the City Council, nor any of the officials, officers, employees, agents or volunteers shall be personally responsible for any liability arising under or by virtue of this Agreement.
3.15.12 Subconsultant Insurance Requirements
(a) Consultant shall not allow any subcontractors or subconsultants to commence work on any subcontract until they have provided evidence satisfactory to the City that they have secured all insurance required under this Section. Policies of commercial general liability insurance provided by such subcontractors or subconsultants shall be endorsed to name the City as an additional insured using ISO form CG 20 38 04 13 or an endorsement providing the exact same coverage. If requested by Consultant, City may approve different scopes or minimum limits of insurance for particular subcontractors or subconsultants.
3.16 Records.
Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to thisAgreement.
Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of five (5) years from the date of final payment under this Agreement.
3.17 Standardized Manufactured Items.
Consultant shall cooperate and consult with City in the use and selection of manufactured items on the Project, including but not limited to, paint, hardware, plumbing, mechanical and electrical equipment, fixtures, roofing materials and floor coverings. All such manufactured items shall be standardized to City’s criteria to the extent such criteria do not interfere with building design.
3.18 Limitation of Agreement.
This Agreement is limited to and includes only the work included in the Project described herein. Any additional or subsequent construction at the site of the Project, or at any other City site, will be covered by, and be the subject of, a separate Agreement for architectural services between City and the Consultant chosen therefor by City.
3.19 Mediation.
Disputes arising from this Agreement may be submitted to mediation if mutually agreeable to the Parties hereto. The type and process of mediation to be utilized shall be subject to the mutual agreement of the Parties.
636
BB&K (2023)
46700.00100\40935196.1
-19-
3.20 Successors and Assigns.
This Agreement shall be binding upon and shall inure to the benefit of the successors in interest, executors, administrators and assigns of each Party to this Agreement. However, Consultant shall not assign or transfer by operation of law or otherwise any or all of its rights, burdens, duties or obligations without the prior written consent of City. Any attempted assignment without such consent shall be invalid and void.
3.21 Asbestos Certification.
Consultant shall certify to City, in writing and under penalty of perjury, that to the best of its knowledge, information and belief no asbestos-containing material or other material deemed to be hazardous by the state or federal government was specified as a building material in any construction document that the Consultant prepares for the Project. Consultant shall require all consultants who prepare any other documents for the Project to submit the same written certification. Consultant shall also assist the City in ensuring that contractors provide City with certification, in writing and under penalty of perjury, that to the best of their knowledge, information and belief no material furnished, installed or incorporated into the Project contains asbestos or any other material deemed to be hazardous by the state or federal government. These certifications shall be part of the final Project submittal. Consultant shall include statements in its specifications that materials containing asbestos or any other material deemed to be hazardous by the state or federal government are not to be included.
3.22 No Third Party Rights.
This Agreement shall not create any rights in, or inure to the benefits of, any third party except as expressly provided herein.
3.23 Governing Law.
This Agreement shall be construed in accordance with, and governed by, the laws of the State of California. Venue shall be in San Bernardino County.
3.24 Exhibits and Recitals.
All exhibits and recitals contained herein and attached hereto are material parts of this Agreement and are incorporated as if fully set forth.
3.25 Severability.
Should any provision in the Agreement be held by a court of competent jurisdiction to be invalid, void, or unenforceable, the remaining provisions shall continue in full force and effect.
3.26 Non-Waiver.
None of the provisions of this Agreement shall be considered waived by either Party, unless such waiver is specifically specified in writing. 637
BB&K (2023)
46700.00100\40935196.1
-20-
3.27 Safety.
Consultant shall execute and maintain its work so as to avoid injury or damage to any person or property. In carrying out its Services, the Consultant shall at all times be in compliance with all applicable local, state and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of its employees, consultant and subcontractors appropriate to the nature of the work and the conditions under which the work is to be performed.
3.28 Harassment Policy.
Consultant shall provide a copy of the City's Harassment Policy to each of its employees assigned to perform the tasks under this Agreement. Consultant shall submit to the City's Personnel Manager a statement signed by each of its employees who are assigned to perform the Services under this Agreement certifying receipt of City's Harassment Policy and certifying that they have read the Harassment Policy. A finding by the City that any of Consultant's employees has harassed a City employee shall be grounds for appropriate discipline, up to and including such employee's removal from performance of this Agreement at City's request.
3.29 Delivery of Notices.
All notices permitted or required under this Agreement shall be given to the respective Parties at the following address, or at such other address as the respective Parties may provide in writing for this purpose:
CITY:
City of Ontario
303 East “B” Street
Ontario, CA 91764
Attn: Adrian Escamilla, Design and Construction
CONSULTANT:
KWWA Architecture
9650 Telstar Ave, Unit A-119
El Monte, CA 91731
Attn: Wing Wong, Principal
Such notice shall be deemed made when personally delivered or when mailed, forty-eight (48) hours after deposit in the U.S. Mail, first class postage prepaid and addressed to the Party at its applicable address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.
3.30 Time of Essence.
Time is of the essence for each and every provision of this Agreement.
3.31 City’s Right to Employ Other Consultants.
City reserves right to employ other consultants, including designers, in connection with this Project or other projects.
3.32 Prohibited Interests.
3.32.1 Solicitation. Consultant maintains and warrants that it has not employed 638
BB&K (2023)
46700.00100\40935196.1
-21-
nor retained any company or person, other than a bona fide employee working solely for Consultant, to solicit or secure this Agreement. Further, Consultant warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability.
3.32.2 Conflict of Interest. For the term of this Agreement, no director, official, officer or employee of City, during the term of his or her service with City, shall have any direct interest in this Agreement, or obtain any present or anticipated material benefit arising therefrom.
3.33 Equal Opportunity Employment.
Consultant represents that it is an equal opportunity employer and that it shall not discriminate against any employee or applicant for employment because of race, religion, color, national origin, ancestry, sex, age or any other classification protected by federal or state law.
Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination. Consultant shall also comply with all relevant provisions of City’s minority business enterprise program, affirmative action plan or other related programs or guidelines currently in effect or hereinafter enacted.
3.34 Labor Certification.
By its signature hereunder, Consultant certifies that it is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker’s Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services.
3.35 Subcontracting.
As specified in this Agreement, Consultant shall not subcontract any portion of the Services required by this Agreement, except as expressly stated herein, without prior written approval of City. Subcontracts, if any, shall contain a provision making them subject to each and every provision of this Agreement.
3.36 Supplemental Conditions.
Any supplemental conditions shall be attached as an exhibit to this Agreement, and that exhibit shall be incorporated herein by reference.
3.37 Entire Agreement.
This Agreement, with its exhibits, contains the entire agreement of the Parties hereto, and supersedes any and all other prior or contemporaneous negotiations, understandings and oral or written agreements between the Parties hereto. Each Party acknowledges that no representations, inducements, promises or agreements have been made by any person which 639
BB&K (2023)
46700.00100\40935196.1
-22-
are not incorporated herein, and that any other agreements shall be void. Furthermore, any modification of this Agreement shall only be effective if in writing signed by all Parties hereto.
SIGNATURES ON FOLLOWING PAGE
640
BB&K (2023) -23-
46700.00100\40935196.1
SIGNATURE PAGE FOR DESIGN SERVICES AGREEMENT
BETWEEN THE CITY OF ONTARIO
AND KWWA ARCHITECTURE
IN WITNESS WHEREOF, the Parties have executed this Agreement as of the date first written above.
CITY OF ONTARIO KWWA ARCHITECTURE
By:
Its:
Printed Name:
By:
Its:
Printed Name:
[If Corporation, TWO SIGNATURES,
President OR Vice President AND Secretary
OR Treasurer REQUIRED]
Approved By:
Scott Ochoa
City Manager
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:
City Clerk
641
BB&K (2023) Exhibit - A
46700.00100\40935196.1
EXHIBIT “A”
SCOPE OF SERVICES
1. GENERAL REQUIREMENTS.
1.1 Basic Services. Consultant agrees to perform all the necessary professional architectural, engineering (e.g. mechanical, electrical, plumbing, structural, site engineering, and any other necessary engineering services mutually agreeable to the Parties) and construction administration services for the Project in a timely and professional manner, consistent with the standards of the profession, including those provided for herein.
1.2 Exclusions from Basic Services. The following services shall be excluded from the basic services listed above: Exclusions will be determined on a project-by-project basis.
1.3 Additional Services. Consultant shall perform the following Additional Services for the Project: Additional Services will be determined on a project by project.
1.4 Communication with City. Consultant shall participate in consultations and conferences with authorized representatives of City and/or other local, regional, or state agencies concerned with the Project, which may be necessary for the completion of the Project or the development of the drawings, specifications and documents in accordance with the applicable standards and requirements of law and the City. Such consultations and conferences shall continue throughout the planning and construction of the Project and the contractor’s warranty period. Consultant shall take direction only from the City’s Representative, or any other representative specifically designated by the City for this Project, including any construction manager hired by the City.
1.5 Coordination and Cooperation with Construction Manager. The City may hire a construction manager to administer and coordinate all or any part of the Project on its behalf. If the City does so, it shall provide a copy of its agreement with the construction manager so that the Consultant will be fully aware of the duties and responsibilities of the construction manager.
The Consultant shall cooperate with the construction manager and respond to any requests or directives authorized by the City to be made or given by the construction manager. The Consultant shall request clarification from the City in writing if the Consultant should have any questions regarding the authority of the construction manager.
2. INITIAL PLANNING PHASE.
During the initial planning phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
2.1 Project Feasibility. Provide advice and assistance to City in determining the feasibility of the Project, analysis of the type and quality of materials and construction to be selected, the site location, and other initial planning matters.
2.2 Meeting Budget and Project Goals. Consultant shall notify City in writing of 642
BB&K (2023) Exhibit - A
46700.00100\40935196.1
potential complications, cost overruns, unusual conditions, and general needs that potentially impact the Project budget and time line, including the City’s Preliminary Construction Budget.
Consultant shall use its best judgment in determining the balance between the size, type and quality of construction to achieve a satisfactory solution within the Project’s budget and construction allowance. It shall be the duty of the Consultant to design the Project within budget.
As discussed herein, including in Section 7.3, if the lowest responsive and responsible bid for the Project exceeds the budget by the stated amount, Consultant may be required to make the necessary changes in the drawing and specifications, at its sole cost and expense, to bring the bids within the required budget.
2.3 Permits, Approvals and Authorizations. As indicated in Section 3.5.4 of the Agreement, Consultant shall assist City in securing easements, encroachment permits, rights of way, dedications, infrastructures and road improvements, as well as coordinating with utilities and adjacent property owners.
3. SCHEMATIC PLAN PHASE.
During the schematic plan phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
3.1 Funding Documents. Consultant shall provide a site plan and all other Projectrelated information necessary and required for an application by City to any federal, state, regional, or local agencies for funds to finance the construction Project.
3.2 Schematic Plans. In cooperation with City, Consultant shall prepare preliminary plans and studies, schematic drawings, site utilization plans, and phasing plans showing the scale and relationship of the components of the Project, the plot plan development at the site, and the proposed architectural concept of the buildings (“Schematic Plans”). Consultant shall incorporate the functional requirements of City into the Schematic Plans. The Schematic Plans shall meet all laws, rules and regulations of the State of California. The Schematic Plans shall show all rooms incorporated in each building of the Project in single-line drawings, and shall include all revisions required by City or by any federal, state, regional or local agency having jurisdiction over the Project. All architectural drawings for the Project shall be in a form suitable for reproduction.
3.3 Preliminary Project Budget. Consultant shall use the City’s Preliminary Construction Budget and its own expertise and experience with the Project to establish a preliminary project budget or allowance in a format required by City (“Consultant’s Preliminary Project Budget”). The purpose of the Consultant’s Preliminary Project Budget is to show the probable Project cost in relation to City’s Preliminary Construction Budget and the construction standards of any applicable funding agency. If Consultant perceives site considerations which render the Project expensive or cost prohibitive, Consultant shall disclose such conditions in writing to City immediately. As discussed herein, including in Section 7.3, if the lowest responsive and responsible bid for the Project exceeds the budget by more than the stated amount, Consultant may be required to make the necessary changes in the drawings and specifications, at its sole cost and expense, to bring the bids within the required budget Consultant shall provide a preliminary written time schedule for the performance of all construction work on the Project.
3.4 Copies of Schematic Plans and Other Documents. Consultant, at its own expense, shall provide a complete set of the Schematic Plans described herein for City’s review and approval. Additionally, at City’s expense, Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any 643
BB&K (2023) Exhibit - A
46700.00100\40935196.1
additional copies required by City shall be provided at actual cost to City.
4. DESIGN DEVELOPMENT PHASE.
During the design development phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
4.1 Design Development Documents. Once City provides Consultant with specific written approval of the Schematic Plans described herein, Consultant shall prepare design development documents consisting of: (1) site and floor plans; (2) elevations; and (3) any other drawings and documents sufficient to fix and describe the types and makeup of materials, as well as the size and character of the Project’s structural, mechanical and electrical systems, and to outline the Project specifications (“Design Development Documents”). The Design Development Documents shall be prepared in sufficient form to present to the City Council for approval.
4.2 Copies of Design Development and Other Documents. Consultant, at its own expense, shall provide a complete set of the Design Development Documents described herein for City’s review and approval. Additionally, at City’s expense, Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any additional copies required by City shall be provided at actual cost to City.
4.3 Updated Project Budget. Consultant shall use its Preliminary Project Budget and expertise and experience with the Project to establish an updated estimate of probable construction costs, containing detail consistent with the Design Development Documents as set forth herein and containing a breakdown based on types of materials and specifications identified herein (“Consultant’s Updated Project Budget”).
4.4 Timetable. Consultant shall provide a written timetable for full and adequate completion of the Project to City.
4.5 Application for Approvals. Consultant shall assist City in applying for and obtaining required approvals from all federal, state, regional or local agencies concerned with the Project. Consultant shall furnish and process all architectural and engineering information required to prepare and process applications to applicable utilities in order to secure priorities and materials, to aid in the construction of the Project and to obtain final Project approval and acceptance by any of the above agencies as may be required.
4.6 Color and Other Aesthetic Issues. Consultant shall provide, for City’s review and approval, a preliminary schedule of all color materials and selections of textures, finishes andother matters involving an aesthetic decision about the Project.
5. FINAL WORKING DRAWINGS AND SPECIFICATIONS.
During the final working drawings and specifications phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
5.1 Final Working Drawings and Specifications. Once City provides Consultant with specific written approval of the Design Development Documents described herein, Consultant shall prepare such complete working drawings and specifications as are necessary for developing complete bids and for properly executing the Project work in an efficient and thorough manner (“Final Working Drawings and Specifications”). Such Final Working Drawings and Specifications 644
BB&K (2023) Exhibit - A
46700.00100\40935196.1
shall be developed from the Schematic Plans and Design Development Documents approved by City. The Final Working Drawings and Specifications shall set forth in detail all of the following:
(1) the Project construction work to be done; (2) the materials, workmanship, finishes, and equipment required for the architectural, structural, mechanical, and electrical systems; and (3) the utility service connection equipment and site work. As indicated inSection 3.9.2 of the Agreement, City may be requested to supply Consultant with the necessary information to determine the proper location of all improvements on and off site, including recorddrawings (“asbuilt drawings”) in City’s possession. Consultant will make a good-faith effort to verify the accuracy of such information by means of a thorough interior and exterior visual surveyof site conditions.
City shall also make a good-faith effort to verify the accuracy of the as-built drawings and provide any supplemental information to Consultant which may not be shown on the as-built drawings.
5.2 Form. The Final Working Drawings and Specifications must be in such form as will enable Consultant and City to secure the required permits and approvals from all federal, state, regional or local agencies concerned with the Project. In addition, the Final Working Drawings and Specifications must be in such form as will enable City to obtain, by competitive bidding, a responsible and responsive bid within the applicable budgetary limitations and cost standards.
The Final Working Drawings and Specifications shall be clear and legible so that uniform copies may be on standard architectural size paper, properly indexed and numbered, andshall be capable of being clearly copied and assembled in a professional manner by Consultant.
5.3 Approval and Revisions. City shall review, study, and check the Final Working Drawings and Specifications presented to it by Consultant, and request any necessary revisions or obtain any necessary approvals by the City Council, subject to the approval of all federal, state, regional or local agencies concerned with the Project. Consultant shall make all City-requested changes, additions, deletions, and corrections in the Final Working Drawings and Specifications at no additional cost, so long as they are not in conflict with the requirements of public agencies having jurisdiction or prior approval, or inconsistent with earlier City direction or Consultant’s professional judgment. Consultant shall bring any such conflicts and/or inconsistencies to the attention of City. The Parties agree that Consultant, and not the City, possesses the requisite expertise to determine the constructability of the Final Working Drawings and Specifications.
However, the City reserves the right to conduct one or more constructability review processes with the Final Working Drawings and Specifications, and to hire an independent architect or other consultant to perform such reviews. Any such independent constructability review shall be at City’s expense. Consultant shall make all City-requested changes, additions, deletions, and corrections in the Final Working Drawings and Specifications which may result from any constructability review, at no additional cost to the City, so long as they are not in conflict with the requirements of public agencies having jurisdiction or prior approval, or inconsistent with earlier City direction or Consultant’s professional judgment. If such changes, additions, deletions or corrections are inconsistent with prior City direction, Consultant shall make such alterations and be compensated therefore pursuant to the Additional Services provision of this Agreement.
5.4 Costs of Construction. It is understood by Consultant that should the Final Working Drawings and Specifications be ordered by City, City shall specify the sum of money set aside to cover the total cost of construction of the work, exclusive of Consultant’s fees. Should it become evident that the total construction cost will exceed the specified sum, Consultant shall at once present a statement in writing to the City’s Representative setting forth this fact and giving a full statement of the cost estimates on which the conclusion is based.
5.5 Copies of Final Working Drawings and Specifications and Other Documents.
Consultant, at its own expense, shall provide a complete set of the Final Working Drawings and 645
BB&K (2023) Exhibit - A
46700.00100\40935196.1
Specifications described herein for City’s review and approval. Additionally, at City’s expense, Consultant shall provide such documents as may be required by any federal, state, regional or local agencies concerned with the Project. Any additional copies required by City shall be provided at actual cost to City.
6. CONSTRUCTION CONTRACT DOCUMENTS.
During the construction contract documents phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
6.1 Bid and Contract Documents. If so required by City, Consultant shall assist City in the completion of all bid and construction documents, including but not limited to, the Notice Inviting Bids, Instructions to Bidders, Contract Bid Forms (including Alternate Bids as requested by City), `Contract, General Conditions, Supplementary General Conditions, Special Conditions, DVBE and other applicable affirmative action documents, Performance Bond, Payment Bond, Escrow Agreement for Security Deposits, and any other certifications and documents required by federal, state and local laws, rules and regulations which may be reasonably required in order to obtain bids responsive to the specifications and drawings. All such documents shall be subject to the approval of City and City’s legal counsel.
6.2 Final Estimate. At the time of delivery of these bid and construction documents, which shall include the Final Working Drawings and Specifications (collectively referred to herein as the “Construction Documents”), Consultant shall provide City with its final estimate of probable construction cost (“Consultant’s Final Estimate”). As discussed herein, including in Section 7.3, it shall be the Consultant’s duty to design the Project within budget.
7. BID PHASE.
During the bid phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
7.1 Reproducible Construction Documents. Once City provides Consultant with specific written approval of the Construction Documents and Consultant’s Final Estimate, Consultant shall provide to City one set of reproducible Construction Documents.
7.2 Distribution of Contract Documents and Review of Bids. Consultant shall assist City in distributing the Construction Documents to bidders and conducting the opening and review of bids for the Project.
7.3 Over Budget. If the apparent lowest responsive and responsible bid on the Project exceeds the Consultant’s Final Estimate by more than five percent (5%), City may request Consultant to amend, at Consultant’s sole cost and expense, the Final Drawings and Specifications in order to rebid the Project and receive a lowest responsive and responsible bid equal to or less than the Consultant’s Final Estimate. All revisions necessary to bring the lowest responsible and responsive bid within the Consultant’s Final Estimate, including any omissions, deferrals or alternates, shall be made in consultation with, and subject to the approval of, the City.
8. CONSTRUCTION PHASE.
During the construction phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
646
BB&K (2023) Exhibit - A
46700.00100\40935196.1
8.1 Observation. The Project Consultant shall observe work executed from the Final Working Drawings and Specifications in person, provided that City may, in its discretion, consent to such observation by another competent representative of Consultant.
8.2 General Administration. Consultant shall provide general administration of the Construction Documents and the work performed by the contractors.
8.3 Pre-Construction Meeting. Consultant shall conduct one or more preconstruction meetings, as the City determines is needed for the Project, with all interested Parties.
8.4 Site Visits of Contractor’s Work. Consultant shall conduct site visits to observe each contractors’ work for general conformance with the Construction Documents and with any approved construction schedules or milestones. Such site visits shall be conducted as often as are necessary and appropriate to the stage of construction, according to the City’s sole discretion, but in no event less than weekly.
8.5 Site Visits of Inspector’s Work. Consultant shall conduct site visits to communicate and observe the activities of the City inspectors. Such site visits shall be conducted as often as is mutually acceptable to Consultant and City. Consultant shall direct the City inspectors and the Project contractors to coordinate the preparation of record drawings indicating dimensions and location of all “as-built” conditions, including but not limited to, underground utility lines.
8.6 Coordination of Subconsultants. Consultant shall cause all architects, engineers and other consultants, as may be hired by Consultant or City, to observe the work completed under their disciplines as required, and approve and review all test results for general conformance with the Construction Documents.
8.7 Reports. Consultant shall make regular reports as may be required by applicable federal, state or local laws, rules or regulations, as well as the federal, state, regional or local agencies concerned with the Project.
8.8 Construction Meetings; Minutes. Consultant shall attend all construction meetings and provide written reports/minutes to the City after each construction meeting in order to keep City informed of the progress of the work. Such meetings shall occur at a frequency necessary for the progress of the Project work, according to the City’s sole discretion, but no less than weekly.
8.9 Written Reports. Consultant shall make written reports to City as necessary to inform City of problems arising during construction, changes contemplated as a result of each such problems, and progress of the Project work.
8.10 Written Records. Consultant shall keep accurate written records of the progress and quality of the Project work and the time schedules, and shall advise the contractors and City of any deviations from the time schedule which could delay timely completion of the Project.
8.11 Material and Test Reports. Consultant shall check and process, in a timely manner, all required material and test reports for the Project work. In addition, Consultant shall provide notice of any deficiencies in material or work reflected in such reports, as well as its recommendation for correction of such deficiencies, to the contractors and City. 647
BB&K (2023) Exhibit - A
46700.00100\40935196.1
8.12 Review and Response to Submissions. Consultant shall review and respond, in a timely manner, to all schedules, submittals, shop drawings, samples, information requests, change requests, and other submissions of the contractor and subcontractors for compliance with, or alterations and additions to, the Construction Documents. Consultant’s review and response shall be done in such a manner so as to ensure the timely and uninterrupted progress of the Project work.
8.13 Rejection of Work. Consultant shall promptly reject, as discussed with City, work or materials which do not conform to the Construction Documents. Consultant shall immediately notify the City and contractor(s) of such rejections. Consultant shall also have the authority to recommend to the City that additional inspection or testing of the work be performed, whether or not such work is fabricated, installed or completed.
8.14 Substitutions. Consultant shall consult with City, in a timely manner, with regard to substitution of materials, equipment and laboratory reports thereof, prior to the City’s final written approval of such substitutions. Consultant’s consultation shall be done in such a manner so as to ensure the timely and uninterrupted progress of the Project work.
8.15 Revised Documents and Drawings. Consultant shall prepare, at no additional expense to City, all documents and/or drawings made necessary by errors and omissions in the originally approved Construction Documents.
8.16 Change Requests and Material Changes. Consultant shall evaluate and advise City, in a timely manner and in writing, of any change requests and material change(s) which may be requested or necessary in the Project plans and specifications. Consultant shall provide the City with its opinion as to whether such change requests should be approved, denied or revised.
If the City has not hired a construction manager or other person to do so, the Consultant shall prepare and execute all change orders and submit them to the City for authorization. If the City has designated a construction manager or other person to prepare all change orders, the Consultant shall review all change orders prepared by such person, execute them and deliver them to the City for authorization if they meet with the Consultant’s approval, or submit them to the City with recommendations for revision or denial if necessary. Consultant shall not order contractors to make any changes affecting the contract price without approval by City of such a written change order, pursuant to the terms of the Construction Documents. Consultant may order, on its own responsibility and pending City Council approval, changes necessary to meet construction emergencies, if written approval of City’s Representative is first secured.
8.17 Applications for Payment. Consultant shall examine, verify and approve contractor’s applications for payment, and shall issue certificates for payment in amounts approved by the City’s inspector.
8.18 Final Color and Product Selection. Consultant shall coordinate final color and product selection with City’s original design concept.
8.19 Substantial Completion. Consultant shall determine the date of substantial completion, in consultation with the City.
8.20 Punch List. After determining that the Project is substantially complete, Consultant shall participate in the inspection of the Project and shall review all remaining deficiencies and minor items needed to be corrected or completed on the Project, including those identified on the punch list prepared by the contractor (“Punch List Items”). Consultant shall notify 648
BB&K (2023) Exhibit - A
46700.00100\40935196.1
contractor in writing that all Punch List Items must be corrected prior to final acceptance of the Project and final payment. Consultant shall also notify City of all Punch List Items.
8.21 Warranties. Consultant shall review materials assembled by the contractor and subcontractors with regard to all written warranties, guarantees, owners’ manuals, instruction books, diagrams, record “as built” drawings, and any other materials required from the contractors and subcontractors pursuant to the Construction Documents. Consultant shall coordinate and provide these materials to the City.
8.22 Certificate of Completion. Consultant shall participate in any further inspections of the Project necessary to issue Consultant’s Certificate of Completion and final certificate for payment.
8.23 Documents for Project Close-Out. Consultant shall cause all other architects, engineers and other consultants, as may be hired by Consultant, to file any and all required documentation with the City or other governmental authorities necessary to close out the Project.
Consultant shall assist the City in obtaining such documentation from all other architects, engineers, or other consultants.
9. AS-BUILT DRAWINGS.
During the as-built drawings phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
9.1 As-Built Drawings and Specifications. Not later than thirty (30) days after substantial completion of the Project, before receipt of final payment, Consultant shall review and forward the Final Working Drawings and Specifications, indicating on them all changes made by change orders or otherwise pursuant to the Construction Documents, as well as all information called for on the specifications, thus producing an “as-built” set of Final Working Drawings and Specifications (“As-Built Drawings and Specifications”). The As-Built Drawings and Specifications shall show, among other things, the location of all concealed pipe, buried conduit runs and other similar elements within the completed Project. Consultant shall personally review and certify that the As-Built Drawings and Specifications are a correct representation of the information supplied to Consultant by any inspectors and the contractor, and shall obtain certifications from any inspectors and the contractor that the drawings are correct.
9.2 Approval. Once City provides Consultant with specific written approval of the AsBuilt Drawings and Specifications, Consultant shall forward to City the complete set of original AsBuilt Drawings and Specifications or a complete set of reproducible duplicate As-Built Drawings and Specifications. The tracing shall be of such quality that clear and legible prints maybe made without appreciable and objectionable loss of detail.
9.3 Documents for Final Payment. Prior to the receipt of Consultant’s final payment, Consultant shall forward to City all of the following: (1) one clear and legible set of reproductions of the computations; (2) the original copy of the specifications; (3) the As-Built Drawings and Specifications as required herein; and (4) Consultant’s Certificate of Completion.
10. WARRANTY PERIOD.
During the warranty period phase of the Project, Consultant shall do all of the following, as well as any incidental services thereto:
649
BB&K (2023) Exhibit - A
46700.00100\40935196.1
10.1 Advice. Consultant shall provide advice to City on apparent deficiencies in the Project during any applicable warranty periods for the Project. 650
BB&K (2023)
46700.00100\40935196.1
Exhibit B-1
EXHIBIT “B”
FEE AND PHASING/FUNDING SCHEDULES
1. FEE SCHEDULE.
Consultant will invoice City on a monthly cycle based on the following fee schedule.
Consultant will include with each invoice a detailed progress report that indicates the amount of budget spent on each phase and the total amount spent against the Total Compensation.
Consultant will inform City regarding any out-of-scope work being performed by Consultant for which Consultant intends to seek compensation from City.
2. PHASING/FUNDING SCHEDULE.
Progress payments towards Total Compensation shall never exceed the following percentages of Total Compensation as of the phase indicated:
651
(BB&K 2020)
46700.00100\33865500.1
652
BB&K (2023)
46700.00100\40935196.1
-1-
CITY OF ONTARIO
DESIGN SERVICES AGREEMENT
1. PARTIES AND DATE.
This Agreement is made and entered into as of , by and between the City of Ontario, a municipal corporation organized and operating under the laws of the State of California with its principal place of business at 303 East “B” Street, Ontario, California 91764- 4196, County of San Bernardino, State of California (“City”), and Architecture Plus, Inc., a corporation with its principal place of business at 1045 Foothill Blvd. La Canada, California 91011 (hereinafter referred to as “Consultant”). City and Consultant are sometimes individually referredto herein as “Party” and collectively as “Parties.”
2. RECITALS.
2.1 City. City is a municipal corporation organized under the laws of the State of California, with power to contract for services necessary to achieve its purpose.
2.2 Consultant. Consultant desires to perform and assume responsibility for the provision of certain professional architectural design services requiredby the City on the terms and conditions set forth in this Agreement. Consultant warrants that it isfully licensed, qualified, and willing to perform the services required by this Agreement; provided, however, that if Consultant is a corporation or other organization, the Project Consultant designated pursuant to Section 3.2, and not the Consultant itself, shall be fully licensed to practiceas an architect in the State of California.
2.3 Project. City desires to engage Consultant to render such services for the On-Call Retail Architect Design Services ("Project") as set forth in this Agreement.
3. TERMS
3.1 Employment of Consultant.
3.1.1 Scope of Services. Consultant promises and agrees to furnish to City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the professional architectural and related services necessary for the full and adequate completion of the Project consistent with the provisions of this Agreement 653
BB&K (2023)
46700.00100\40935196.1
-2-
(hereinafter referred to as “Services”). The Services are more particularly described throughout this Agreement, including Exhibit “A” attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordancewith, this Agreement, any exhibits attached hereto and incorporated herein by reference, and allapplicable local, state and federal laws, rules and regulations. All Services performed by Consultant shall be subject to the sole and discretionary approval of the City, which approval shallnot be unreasonably withheld.
3.1.2 Term. The term of this Agreement shall be from July 16, 2024 to July 16, 2027, The City shall have the unilateral option, at its sole discretion, to renew this Agreement automatically for no more than two additional one-year terms unless earlier terminated as provided herein. Consultant shall complete the Services within the term of agreement and shall meet any other established scheduled and deadlines.
3.2 Project Consultant; Key Personnel.
3.2.1 Retail Architect. Consultant shall name a specific individual to act as Project Consultant, subject to the approval of City. Consultanthereby designates Greg Powell (License No. #C28099) to act as the Retail Architect for the Project. The Architect shall: (1) maintain oversight of the Services; (2) have full authority to represent and act on behalf of the Consultant for all purposes under thisAgreement; (3) supervise and direct the Services using his or her best skill and attention; (4) be responsible for the means, methods, techniques, sequences and procedures used for theServices; (5) adequately coordinate all portions of the Services; and (6) act as principal contact with y and all contractors, consultants, engineers and inspectors on the Project.
Any change in the Retail Architect shall be subject to the City’s prior written approval, which approval shall not be unreasonably withheld. The new Retail Architect shall be of at least equal competence as the prior Retail Architect. In the event that City and Consultant cannotagree as to the substitution of a new Retail Architect. City shall be entitled to terminate this Agreement for cause.
3.2.2 Key Personnel. In addition to the Retail Architect, Consultant has represented to the City that certain additional key personnel, engineers and consultants will perform the Services under this Agreement. Should one or more of such personnel, engineers or consultants become unavailable, Consultant may substitute others of atleast equal competence upon written approval of the City. In the event that City and Consultant cannot agree as to the substitution of key personnel, engineers or consultants, City shall be entitled to terminate this Agreement for cause. The key additional personnel, engineers and consultants for performance of this Agreement are as follows: Greg Powell, Architect
3.3 Hiring of Consultants and Personnel.
3.3.1 Right to Hire or Employ. Consultant shall have the option, unless City objects in writing after notice, to employ at its expense architects, engineers, experts or other consultants qualified and licensed to render services in connection with the planning and/or administration of the Project, and to delegate to them such duties as Consultant may delegate without relieving Consultant from administrative or other responsibility under this Agreement.
Consultant shall be responsible for the coordination and cooperation of Consultant’s architects, engineers, experts or other consultants. All consultants, including changes in consultants, shall be subject to approval by City in its sole and reasonable discretion. Consultant shall notify City of the identity of all consultants at least fourteen (14) days prior to their commencement of work 654
BB&K (2023)
46700.00100\40935196.1
-3-
to allow City to review their qualifications and approve to their participation on the Project in its sole and reasonable discretion.
3.3.2 Qualification and License. All architects, engineers, experts and other consultants retained by Consultant in performance of this Agreement shall be qualified to perform the Services assigned to them, and shall be licensed to practice in their respective professions, where required by law.
3.3.3 Standards and Insurance. All architects, engineers, experts and other consultants hired by Consultant shall be required to meet all of the same standards and insurance requirements set forth in this Agreement, unless other standards or requirements are approved by the City in writing. Unless changes are approved in writing by the City, Consultant’s agreements with its consultants shall contain a provision making them subject to all provisions stipulated in this Agreement.
3.3.4 Assignments or Staff Changes. Consultant shall promptly obtain written City approval of any assignment, reassignment or replacement of such architects, engineers, experts and consultants, or of other staff changes of key personnel working on the Project. As provided in the Agreement, any changes in Consultant’s consultants and key personnel shall be subject to approval by City.
3.3.5 Draftsman and Clerical Support. Draftsmen and clerical personnel shall be retained by Consultant at Consultant’s sole expense.
3.4 Standard of Care.
3.4.1 Standard of Care. Consultant shall perform all Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals qualified to perform the Services in the same discipline in the State of California, and shall be responsible to City for damages sustained by the City and delays to the Project as specified in the indemnification provision of this Agreement. Without limiting the foregoing, Consultant shall be fully responsible to the City for any increased costs incurred by the City as a result of any such delays in the design or construction of the Project. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services. Consultant warrants and represents that all of its employees, architects, engineers, experts and other consultants shall have sufficient skill and experience to perform the Services assigned to them. Finally, Consultant represents that it, its employees, architects, engineers, experts and other consultants have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services assigned to or rendered by them and that such licenses and approvals shall be maintained throughout the term of this Agreement. As provided for in the indemnification provisions of this Agreement, Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant’s failure to comply with the standard of care provided for herein.
3.4.2 Performance of Employees. Any employee or consultant who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee or 655
BB&K (2023)
46700.00100\40935196.1
-4-
consultant who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed from the Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.
3.5 Laws and Regulations.
3.5.1 Knowledge and Compliance. Consultant shall keep itself fully informed of and in compliance with all applicable local, state and federal laws, rules and regulations in any manner affecting the performance of the Services or the Project, and shall give all notices required of the Consultant by law. Consultant shall be liable, pursuant to the standard of care and indemnification provisions of this Agreement, for all violations of such laws and regulations in connection with its Services. Consultant shall defend, indemnify and hold City, its officials, officers, employees and agents free and harmless, pursuant to the indemnification provisions of this Agreement, from any claim or liability arising out of any failure or alleged failure to comply with such laws, rules or regulations.
3.5.2 Drawings and Specifications. Consultant shall cause all drawings and specifications to conform to any applicable requirements of federal, state and local laws, rules and regulations, including the Uniform Building Code, in effect as of the time the drawings and specifications are prepared or revised during the latest phase of the Services described in Exhibit “A” attached hereto. Any significant revisions made necessary by changes in such laws, rules and regulations after this time may be compensated as Additional Services which were not knownor reasonably should not have been known by Consultant. Consultant shall cause the necessary copies of such drawings and specifications to be filed with any governmental bodies with approval jurisdiction over the Project, in accordance with the Services described in Exhibit “A” attached hereto. For the preparation of all such drawings and specifications, the Consultant shall use Computer Aided Design Drafting (“CADD”) (e.g., AutoCAD) or other technology acceptable to the Consultant and City.
3.5.3 Americans with Disabilities Act. Consultant will use its best professional efforts to interpret all applicable federal, state and local laws, rules and regulations with respect to access, including those of the Americans with Disabilities Act (“ADA”). Consultant shall inform City of the existence of inconsistencies of which it is aware or reasonably should be aware between federal and state accessibility laws, rules and regulations, as well as any other issues which are subject to conflicting interpretations of the law, and shall provide the City with its interpretation of such inconsistencies and conflicting interpretations. Unless Consultant brings such inconsistencies and conflicting interpretations to the attention of the City and requests City’s direction on how to proceed, the Consultant’s interpretation of such inconsistencies and conflicting interpretations shall be the sole responsibility and liability of Consultant, and the Consultant shall correct all plans, specifications and other documents prepared for the Project at no additional cost if its interpretations are shown to be incorrect. In the event that the Consultant request’s City’s direction on how to proceed with respect to any inconsistent and/or conflicting interpretation, the Consultant shall be responsible to the City only pursuant to the indemnification provisions of this Agreement.
3.5.4 Permits, Approvals and Authorizations. Consultant shall provide City with a list of all permits, approvals or other authorizations required for the Project from all federal, stateor local governmental bodies with approval jurisdiction over the Project. Consultant shall then assist 656
BB&K (2023)
46700.00100\40935196.1
-5-
the City in obtaining all such permits, approvals and other authorizations. The costs of such permits, approvals and other authorizations shall be paid by the City.
3.5.5 Water Quality Management and Compliance. Consultant shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Services including, without limitation, all applicable provisions of the City’s ordinances regulating water quality and storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251 et seq.); the California Porter-Cologne Water Quality Control Act (Cal Water Code §§ 13000- 14950); and any and all regulations, policies, or permits issued pursuant to any such authority.
Consultant shall additionally comply with the lawful requirements of the City, and any other municipality, drainage district, or other local agency with jurisdiction over the location where the Services are to be conducted, regulating water quality and storm water discharges. Failure to comply with laws, regulations, and ordinances listed in this Section is a violation of federal and state law.
3.6 Independent Contractor.
3.6.1 Control and Payment of Subordinates. City retains Consultant on an independent contractor basis and Consultant is not an employee of City. Consultant is not an employee for state tax, federal tax or any other purpose, and is not entitled to the rights or benefits afforded to City’s employees. Any additional personnel performing the Services under this Agreement on behalf of Consultant shall also not be employees of City, and shall at all times be under Consultant’s exclusive direction and control. Consultant shall pay all wages, salaries, and other amounts due such personnel in connection with their performance of Services under this Agreement and as required by law. Consultant shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers’ compensation insurance.
3.7 Schedule of Services.
3.7.1 Consultant Services. Consultant shall fully and adequately complete the Services described in this Agreement and in Exhibit “A” attached hereto and incorporated herein by reference.
3.7.2 Timely Performance Standard. Consultant shall perform all Services hereunder as expeditiously as is consistent with professional skill and care, as well as the orderly progress of the Project work so as not to be the cause, in whole or in part, of delays in the completion of the Project or in the achievement of any Project milestones, as provided herein.
Specifically, Consultant shall perform its Services so as to allow for the full and adequate completion of the Project within the time required by the City and within any completion schedules adopted for the Project. Consultant agrees to coordinate with City’s staff, contractors and consultants in the performance of the Services, and shall be available to City’s staff, contractors and consultants at all reasonable times.
3.7.3 Performance Schedule. Consultant shall prepare an estimated time schedule for the performance of Consultant’s Services, to be adjusted as the Project proceeds.
Such schedule shall be subject to the City’s review and approval, which approval shall not be unreasonably withheld, and shall include allowances for periods of time required for City’s review and approval of submissions, and for approvals of authorities having jurisdiction over Project 657
BB&K (2023)
46700.00100\40935196.1
-6-
approval and funding. If City and Consultant cannot mutually agree on a performance schedule, City shall have the authority to immediately terminate this Agreement. The schedule shall not be exceeded by Consultant without the prior written approval of City. If the Consultant’s Services are not completed within the time provided by the agreed upon performance schedule, or any milestones established therein, it is understood, acknowledged and agreed that the City will suffer damage for which the Consultant will be responsible.
3.7.4 Excusable Delays. Any delays in Consultant’s work caused by the following may be added to the time for completion of any obligations of Consultant: (1) the actionsof City or its employees; (2) the actions of those in direct contractual relationship with City; (3) theactions of any governmental agency having jurisdiction over the Project; (4) the actions of any parties not within the reasonable control of the Consultant; and (5) any Force Majeure Event (asdefined herein) or other unforeseen occurrence not due to any fault or negligence on the part of Consultant. Neither the City nor the Consultant shall be liable for damages, liquidated or otherwise, to the other on account of such delays.
3.7.5 Force Majeure Events. Neither City nor Consultant shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the non-performing Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Consultant and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the Services and Agreement. Should a Force Majeure Event occur, the nonperforming Party shall, within fifteen (15) calendar days of the beginning of an Force Majeure Event, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events shall not entitle Consultant to any additional compensation. Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement.
3.7.6 Request for Excusable Delay Credit. The Consultant shall, within fifteen (15) calendar days of the beginning of any excusable delay, notify the City in writing of the causes of delay (unless City grants in writing a further period of time to file such notice prior to the date of final payment under the Agreement). City will then ascertain the facts and the extent of the delay, and grant an extension of time for completing the Services when, in its sole judgment, the findings of fact justify such an extension. The City’s findings of fact thereon shall be final and conclusive on the Parties. Extensions of time shall apply only to that portion of the Services affected by the delay and shall not apply to other portions of the Services not so affected. The sole remedy of Consultant for extensions of time shall be an extension of the performance time at no cost to the City. If Additional Services are required as a result of an excusable delay, the Parties shall mutually agree thereto pursuant to the Additional Services provision of this Agreement. Should Consultant make an application for an extension of time, Consultant shall submit evidence that the insurance policies required by this Agreement remain in effect during 658
BB&K (2023)
46700.00100\40935196.1
-7-
the requested additional period of time.
3.8 Additional Services.
3.8.1 Request for Services. At City’s request, Consultant may be asked to perform services not otherwise included in this Agreement, not included within the basic services listed in Exhibit “A” attached hereto, and/or not customarily furnished in accordance with generally accepted architectural practice.
3.8.2 Definition. As used herein, “Additional Services” mean: (1) any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary for the Consultant to perform at the execution of this Agreement; or (2) any work listed as Additional Services in Exhibit “A” attached hereto. Consultant shall not perform, nor be compensated for, Additional Services without prior written authorization from City and without an agreement between the City and Consultant as to the compensation to be paid for such services. City shall pay Consultant for any approved Additional Services, pursuant to the compensation provisions herein, so long as such services are not made necessary through the fault of Consultant pursuant to the indemnification provision of this Agreement.
3.8.3 Examples of Additional Services. Such Additional Services shall notinclude any redesign or revisions to drawings, specifications or other documents when such revisions are necessary in order to bring such documents into compliance with applicable laws, rules, regulations or codes of which Consultant was aware or should have been aware pursuantto the laws and regulations provision of this Agreement above. Such Additional Services may include, but shall not be limited to:
(a) Separately Bid Portions of Project. Plan preparation and/or administration of work on portions of the Project separately bid. (b) Furniture and Interior Design. Assistance to City, if requested, for the selection of moveable furniture, equipment or articles which are not included in the Construction Documents.
(c) Fault of Contractor. Services caused by delinquency, default or insolvency of contractor, or by major defects in the work of the contractor, provided that any such services made necessary by the failure of Consultant to detect and report such matters when it reasonably should have done so shall not be compensated. (d) Inconsistent Approvals or Instructions. Revisions in drawings, specifications or other documents when such revisions are inconsistent with written approvals or instructions previously given and are due to causes beyond the control of Consultant. (e) Legal Proceedings. Serving as an expert witness on City's behalf or attending legal proceedings to which the Consultant is not a party. (f) Damage Repair. Supervision of repair of damages to any structure. (g) Extra Environmental Services. Additional work required for environmental conditions (e.g. asbestos or site conditions) not already contemplated within the Consultant's services for the Project.
659
BB&K (2023)
46700.00100\40935196.1
-8-
3.9 City Responsibilities. City’s responsibilities shall include the following:
3.9.1 Data and Information. City shall make available to Consultant all necessary data and information concerning the purpose and requirements of the Project, including scheduling and budget limitations, objectives, constraints and criteria. As part of the budget limitation information, the City shall provide the Consultant with a preliminary construction budget (“City’s Preliminary Construction Budget”).
3.9.2 Project Survey. If required pursuant to the scope of the Project and if requested by Consultant, City shall furnish Consultant with, or direct Consultant to procure at City’s expense, a survey of the Project site prepared by a registered surveyor or civil engineer, any other record documents which shall indicate existing structures, land features, improvements, sewer, water, gas, electrical and utility lines, topographical information and boundary dimensions of the site, and any other such pertinent information.
3.9.3 Bid Phase. Distribute Construction Documents to bidders and conduct the opening and review of bids for the Project.
3.9.4 Testing. Retain consultant(s) to conduct chemical, mechanical, soils, geological or other tests required for proper design of the Project, and furnish such surveys, borings, test pits, and other tests as may be necessary to reveal conditions of the site which must be known to determine soil condition or to ensure the proper development of the required drawings and specifications.
3.9.5 Required Inspections and Tests. Retain consultant(s) to conduct materials testing and inspection or environmental/hazardous materials testing and inspection pursuant to any applicable laws, rules or regulations.
3.9.6 Fees of Reviewing or Licensing Agencies. Directly pay or reimburse the payment of all fees required by any reviewing or licensing agency, or other agency having approval jurisdiction over the Project.
3.9.7 City’s Representative. The City hereby designates the City Manager, or his or her designee, to act as its representative for the performance of this Agreement (“City’s Representative”). City’s Representative shall have the power to act on behalf of the City for all purposes under this Contract. The City Manager hereby designates Tito Haes , Executive Director Public Works, or his or her designee, as the City’s contact for the implementation of the Services hereunder. Contractor shall not accept direction or orders from any person other than the City’s Representative or his or her designee.
3.9.8 Review and Approved Documents. Review all documents submitted by Consultant, including change orders and other matters requiring approval by the City Council or other officials. City shall advise Consultant of decisions pertaining to such documents within a reasonable time after submission, so as not to cause unreasonable delay as provided in the excusable delay provisions of this Agreement above.
3.10 Compensation.
3.10.1 Consultant’s Compensation for Basic Services. City shall pay to Consultant, for the performance of all Services rendered under this Agreement, the total not to exceed amount of One Hundred Fifty Thousand Dollars ($150,000) (“Total Compensation”). 660
BB&K (2023)
46700.00100\40935196.1
-9-
This Total Compensation amount shall be based upon, and may be adjusted according to, the fee schedule and related terms and conditions attached hereto as Exhibit “B” and incorporated herein by reference. The Total Compensation, as may be adjusted upon mutual agreement, shall constitute complete and adequate payment for Services under thisAgreement.
3.10.2 Payment for Additional Services. At any time during the term of this Agreement, City may request that Consultant perform Additional Services. As used herein, Additional Services means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement. Any additional work in excess of this amount must be approved by the City. If authorized, such Additional Services will be compensated at the rates and in the manner set forth in Exhibit “B” attached hereto and incorporated herein by reference, unless a flat rate or some other form of compensation is mutually agreed upon by the Parties. IfCity requires Consultant to hire consultants to perform any Additional Services, Consultant shall be compensated therefore at the rates and in the manner set forth in Exhibit “B” attached heretoand incorporated herein by reference, unless a flat rate or some other form of compensation is mutually agreed upon by the Parties. City shall have the authority to review and approve the rates of any such consultants. In addition, Consultant shall be reimbursed for any expenses incurred by such consultants pursuant to the terms and conditions of Section 3.10.3.
3.10.3 Reimbursable Expenses. Reimbursable expenses are in addition to compensation for the Services and Additional Services. Consultant shall not be reimbursed for any expenses unless authorized in writing by City, which approval may be evidenced by inclusion in Exhibit “B” attached hereto. Such reimbursable expenses shall include only those expenses which are reasonably and necessarily incurred by Consultant in the interest of the Project.
Consultant shall be required to acquire prior written consent in order to obtain reimbursement for the following: (1) extraordinary transportation expenses incurred in connection with the Project; (2) out-of-town travel expenses incurred in connection with the Project; (3) fees paid for securing approval of authorities having jurisdiction over the Project; (4) bid document duplication costs in excess of $1,000; and (5) other costs, fees and expenses in excess of $1,000.
3.10.4 Payment to Consultant. Consultant’s compensation and reimbursable expenses shall be paid by City to Consultant no more often than monthly. Such periodic payments shall be made based upon the percentage of work completed, and in accordance with the phasing and funding schedule provided in Exhibit “B” and the compensation rates indicated in Exhibit “B” attached hereto and incorporated herein by reference. In order to receive payment, Consultant shall present to City an itemized statement which indicates Services performed, percentage of Services completed, method for computing the amount payable, and the amount to be paid. The statement shall describe the amount of Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement, as well as those expenses for which reimbursement is requested for that statement period. The amount paid to Consultant shall never exceed the percentage amounts authorized by the phasing and funding schedule located in Exhibit “B” attached hereto. City shall, within thirty (30) days of receiving such statement, review the statement and pay all approved charges thereon pursuant to the provisions of Civil Code Section 3320. Disputed amounts shall be resolved by the Parties in a mutually agreeable manner.
Payments made for Additional Services shall be made in installments, not more often than monthly, proportionate to the degree of completion of such services or in such other manner as the Parties shall specify when such services are agreed upon, and in accordance with any authorized fee or rate schedule. In order to receive payment, Consultant shall present to City an 661
BB&K (2023)
46700.00100\40935196.1
-10-
itemized statement which indicates the Additional Services performed, percentage of Additional Services completed, method for computing the amount payable, and the amount to be paid. The statement shall describe the amount of Additional Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement. City shall, within thirty (30) days of receiving such statement, review the statement and pay all approved charges thereon pursuant to the provisions of Civil Code Section 3320. Disputed amounts shall be resolved by the Parties in a mutually agreeable manner.
Upon cancellation or termination of this Agreement, Consultant shall be compensated as set forth in the termination provision herein.
3.10.5 Withholding Payment to Consultant. The City may withhold payment, in whole or in part, to the extent reasonably necessary to protect the City from claims, demands, causes of action, costs, expenses, liabilities, losses, damages, or injuries of any kind to the extent arising out of or caused by the negligence, recklessness, or willful misconduct protected under the indemnification provisions of this Agreement. Failure by City to deduct any sums from a progress payment shall not constitute a waiver of the City’s right to such sums. The City may keep any moneys which would otherwise be payable at any time hereunder and apply the same,or so much as may be necessary therefor, to the payment of any expenses, losses, or damagesas determined by the City, incurred by the City for which Consultant is liable under the Agreementor state law. Payments to the Consultant for compensation and reimbursable expenses due shallnot be contingent on the construction, completion or ultimate success of the Project. Payment tothe Consultant shall not be withheld, postponed, or made contingent upon receipt by the City of offsetting reimbursement or credit from Parties not within the Consultant’s reasonable control.
3.10.6 Prevailing Wages. Consultant is aware of the requirements of California Labor Code Sections 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., (“Prevailing Wage Laws”), which require the payment of prevailing wage rates and the performance of other requirements on certain “public works” and “maintenance” projects. If the Services are being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and if the total compensation is $1,000 or more, Consultant agrees to fully complywith and to require its consultants to fully comply with such Prevailing Wage Laws. City shall provide Consultant with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Consultant shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services available to interested parties upon request, and shall post copies at the Consultant’s principal place of business and at the Project site. It shall be mandatory upon the Consultant and all subconsultants to comply with all California Labor Code provisions, which include but are not limited to prevailing wages (Labor Code Sections 1771, 1774 and 1775), employment of apprentices (Labor Code Section 1777.5), certified payroll records (Labor Code Sections 1771.4and 1776), hours of labor (Labor Code Sections 1813 and 1815) and debarment of contractors and subcontractors (Labor Code Section 1777.1). The requirement to submit certified payroll records directly to the Labor Commissioner under Labor Code section 1771.4 shall not apply to work performed on a public works project that is exempt pursuant to the small project exemption specified in Labor Code Section 1771.4. Consultant shall defend, indemnify and hold the City, itselected officials, officers, employees and agents free and harmless from any claims, liabilities, costs, penalties or interest arising out of any failure or alleged failure of the Consultant or its consultants to comply with the Prevailing Wage Laws. (a) Registration/DIR Compliance. If the Services are being performed as part of an applicable “public works project” of over $25,000 when the project is for construction, 662
BB&K (2023)
46700.00100\40935196.1
-11-
alteration, demolition, installation, or repair work, or a public works project of over $15,000 when the project is for maintenance work, in addition to the foregoing, then pursuant to Labor Code sections 1725.5 and 1771.1, the Consultant and all subconsultants performing such Services must be registered with the Department of Industrial Relations (“DIR”). Consultant shall maintain registration for the duration of the Project and require the same of any subconsultants. This project may also be subject to compliance monitoring and enforcement by the DIR. It shall be Consultant’s sole responsibility to comply with all applicable registration and labor compliance requirements, including the submission of payroll records directly to the DIR. Any stop orders issued by the Department of Industrial Relations against Consultant or any subconsultant that affect Consultant’s performance of services, including any delay, shall be Consultant’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Consultant caused delay and shall not be compensable by the City. Consultant shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the Department of Industrial Relations against Consultant or any subconsultant.
3.11 Notice to Proceed.
Consultant shall not proceed with performance of any Services under this Agreement unless and until the City provides a written notice to proceed.
3.12 Termination, Suspension and Abandonment.
3.12.1 Grounds for Termination; Consultant’s Termination for Cause. City hereby reserves the right to suspend or abandon, at any time and for any reason, all or any portion of the Project and the construction work thereon, or to terminate this Agreement at any time with or without cause. Consultant shall be provided with at least seven (7) days advanced written notice of such suspension, abandonment or termination. In the event of such suspension, abandonment or termination, Consultant shall be paid for Services and reimbursable expenses rendered up to the date of such suspension, abandonment or termination, pursuant to the schedule of payments provided for in this Agreement, less any claims against or damages suffered by City as a result of the default, if any, by Consultant. Consultant hereby expressly waives any and all claims for damages or compensation arising under this Agreement, except as set forth herein, in the event of such suspension, abandonment or termination. Consultant may terminate this Agreement for substantial breach of performance by the City such as failure to make payment to Consultant as provided in this Agreement.
3.12.2 City’s Suspension of Work. If Consultant’s Services are suspended by City, City may require Consultant to resume such Services within ninety (90) days after written notice from City. When the Project is resumed, the Total Compensation and schedule of Services shall be equitably adjusted upon mutual agreement of the City and Consultant.
3.12.3 Documents and Other Data. Upon suspension, abandonment or termination, Consultant shall provide to City all preliminary studies, sketches, working drawings, specifications, computations, and all other Project Documents, as defined below, to which City would have been entitled at the completion of Consultant’s Services under this Agreement. Upon payment of the amount required to be paid to Consultant pursuant to the termination provisions of this Agreement, City shall have the rights, as provided in this Agreement hereinafter, to use such Project Documents prepared by or on behalf of Consultant under this Agreement. Consultant shall make such documents available to City upon request and without additional compensation other than as may be approved as a reimbursable expense. 663
BB&K (2023)
46700.00100\40935196.1
-12-
3.12.4 Employment of other Consultants. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated.
3.13 Ownership and Use of Documents; Confidentiality.
3.13.1 Ownership. All plans, specifications, original or reproducibletransparencies of working drawings and master plans, preliminary sketches, architectural presentation drawings, structural computations, estimates and any other documents prepared pursuant to this Agreement, including, but not limited to, any other works of authorship fixed in any tangible medium of expression such as writings, physical drawings and data magnetically orotherwise recorded on computer diskettes (hereinafter referred to as the “Project Documents”) shall be and remain the property of City. Although the official copyright in all Project Documentsshall remain with the Consultant or other applicable subcontractors or consultants, the Project Documents shall be the property of City whether or not the work for which they were made is executed or completed. Within thirty (30) calendar days following completion of the Project, Consultant shall provide to City copies of all Project Documents required by City. In addition, Consultant shall retain copies of all Project Documents on file for a minimum of fifteen (15) years following completion of the Project, and shall make copies available to City upon the payment ofreasonable duplication costs. Before destroying the Project Documents following this retention period, Consultant shall make a reasonable effort to notify City and provide City with the opportunity to obtain the documents.
3.13.2 Right to Use. Consultant grants to City the right to use and reuse all or part of the Project Documents, at City’s sole discretion and with no additional compensation to Consultant, for the following purposes:
(a) The construction of all or part of this Project.
(b) The repair, renovation, modernization, replacement, reconstruction or expansion of this Project at any time;
(c) The construction of another project by or on behalf of the City for its ownership and use;
City is not bound by this Agreement to employ the services of Consultant in the event such documents are used or reused for these purposes. City shall be able to use or reuse the Project Documents for these purposes without risk of liability to the Consultant or third parties with respect to the condition of the Project Documents, and the use or reuse of the Project Documents for these purposes shall not be construed or interpreted to waive or limit City’s right to recover for latent defects or for errors or omissions of the Consultant.
Any use or reuse by City of the Project Documents on any project other than this Project without employing the services of Consultant shall be at City’s own risk with respect to third parties. If City uses or reuses the Project Documents on any project other than this Project, it shall remove the Consultant’s seal from the Project Documents and hold harmless Consultant and its officers, directors, agents and employees from claims arising out of the negligent use or re-use of the Project Documents on such other project.
3.13.3 License. This Agreement creates a non-exclusive and perpetual license for 664
BB&K (2023)
46700.00100\40935196.1
-13-
City to copy, use, modify or reuse any and all Project Documents and any intellectual property rights therein. Consultant shall require any and all subcontractors and consultants to agree in writing that City is granted a non-exclusive and perpetual license for the work of such subcontractors or consultants performed pursuant to this Agreement.
3.13.4 Right to License. Consultant represents and warrants that Consultant has the legal right to license any and all copyrights, designs and other intellectual property embodied in the Project Documents that Consultant prepares or causes to be prepared pursuant to this Agreement. Consultant shall indemnify and hold City harmless pursuant to the indemnification provisions of this Agreement for any breach of this Section. Consultant makes no such representation and warranty in regard to previously prepared designs, plans, specifications, studies, drawings, estimates or other documents that were prepared by design professionals other than Consultant and provided to Consultant by City.
3.13.5 Confidentiality. All Project Documents, either created by or provided to Consultant in connection with the performance of this Agreement, shall be held confidential by Consultant to the extent they are not subject to disclosure pursuant to the Public Records Act. All Project Documents shall not, without the written consent of City, be used or reproduced by Consultant for any purposes other than the performance of the Services. Consultant shall not disclose, cause or facilitate the disclosure of the Project Documents to any person or entity not connected with the performance of the Services or the Project. Nothing furnished to Consultant which is otherwise known to Consultant or is generally known, or has become known, to the related industry shall be deemed confidential. Consultant shall not use City’s name or insignia, photographs of the Project, or any publicity pertaining to the Services or the Project in any magazine, trade paper, newspaper, television or radio production or other similar medium without the written consent of City.
3.14 Indemnification.
3.14.1 To the fullest extent permitted by law, Consultant shall defend (with counsel of City’s choosing), indemnify and hold the City, its officials, officers, employees, volunteers, and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Consultant, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Consultant’s Services, the Project or this Agreement, including without limitation the payment of all damages, expert witness fees and attorney’s fees and other related costs and expenses except such loss or damage caused by the sole negligence or willful misconduct of the City. Consultant's obligation to indemnify shall survive expiration or termination of this Agreement and shall not be restricted to insurance proceeds, if any, received by Consultant, the City, its officials, officers, employees, agents, or volunteers.
3.14.2 If Consultant’s obligation to defend, indemnify, and/or hold harmless arises out of Consultant’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Consultant’s indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Consultant, and, upon Consultant obtaining a final adjudication by a court of competent jurisdiction, Consultant’s liability for such claim, including the cost to defend, shall not exceed the Consultant’s proportionate percentage of fault.
665
BB&K (2023)
46700.00100\40935196.1
-14-
3.15 Insurance. Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this Section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurancerequired under this section.
3.15.1 Types of Insurance Required. As a condition precedent to the effectiveness of this Agreement for work to be performed hereunder, and without limiting the indemnity provisions of the Agreement, Consultant shall, at its expense, procure and maintain infull force and effect for the duration of the Agreement the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Consultant agrees to amend, supplement or endorse the policies to do so.
3.15.2 Additional Insured. The City of Ontario, its officials, officers, employees, agents, and volunteers shall be named as additional insureds on Consultant’s and its subconsultants’ policies of commercial general liability and automobile liability insurance using the endorsements and forms specified herein or exact equivalents.
3.15.3 Commercial General Liability
(a) The Consultant shall take out and maintain, during the performance of all work under this Agreement, in amounts not less than specified herein, Commercial General Liability Insurance, in a form and with insurance companies acceptable to the City. (b) Coverage for Commercial General Liability insurance shall be at least as broad as the following: Insurance Services Office Commercial General Liability coverage (Occurrence Form CG 00 01) or exact equivalent. Commercial General Liability Insurance must include coverage for the following:
(i) Bodily Injury and Property Damage
(ii) Personal Injury/Advertising Injury
(iii) Premises/Operations Liability
(iv) Products/Completed Operations Liability
(v) Aggregate Limits that Apply per Project
(vi) Explosion, Collapse and Underground (UCX) exclusion deleted
(vii) Contractual Liability with respect to this Contract (viii) Broad Form Property Damage
(ix) Independent Consultants Coverage
(c) The policy shall contain no endorsements or provisions limiting coverage for (1) contractual liability; (2) cross liability exclusion for claims or suits by one insured against another; (3) products/completed operations liability; or (4) contain any other exclusion 666
BB&K (2023)
46700.00100\40935196.1
-15-
contrary to the Agreement.
(d) The policy shall give City, the City Council and each member of the City Council, its officers, employees, agents and City designated volunteers additional insured status using ISO endorsement forms CG 20 10 10 01 and 20 37 10 01, or endorsements providing the exact same coverage.
(e) The general liability program may utilize either deductibles or provide coverage excess of a self-insured retention, subject to written approval by the City, and provided that such deductibles shall not apply to the City as an additional insured.
3.15.4 Automobile Liability
(a) At all times during the performance of the work under this Agreement, the Consultant shall maintain Automobile Liability Insurance for bodily injury and property damage including coverage for owned, non-owned and hired vehicles, in a form and with insurance companies acceptable to the City.
(b) Coverage for automobile liability insurance shall be at least as broad as Insurance Services Office Form Number CA 00 01 covering automobile liability (Coverage Symbol 1, any auto).
(c) The policy shall give City, the City Council and each member of the City Council, its officers, employees, agents and City designated volunteers additional insured status.
(d) Subject to written approval by the City, the automobile liability program may utilize deductibles, provided that such deductibles shall not apply to the City as an additional insured, but not a self-insured retention.