Agenda packet — City Council and Concurrent Authorities, December 9, 2025 (part 5 of 6)

730
Local Construction Contract – ABIDE BUILDERS, INC. – PROJECT NO. WP13270 (Updated 10/18/23) It is further agreed that in case the work called for under the contract is not finished and completed in all parts and requirements within the number of days as specified, the CITY shall have the right to increase the number of days or not, as may seem best to serve the interest of CITY, and if the CITY decides to increase the said number of days, the CITY shall further have the right to charge to CONTRACTOR, CONTRACTOR's heirs, assigns or sureties, and to deduct from the final payment for the work, all or any part, as may be deemed proper, the liquidated damages as specified or the actual cost of engineering, inspection, superintendence, and other overhead expenses which are directly chargeable to the contract, and which accrue during the period of such extension, whichever is greater, except the cost of final surveys and preparation of final estimate shall not be included in such charges.

A working day shall not include, nor shall CONTRACTOR be assessed with liquidated damages nor the additional cost of engineering and inspection during any delay beyond the time named for the completion of the work caused by acts of God or of the public enemy, acts of CITY, fire, floods, epidemics, quarantine restrictions, strikes, and freight embargoes and subject to approval by the Director of Public Works, inability to get materials ordered by CONTRACTOR or subcontractor due to such causes provided that CONTRACTOR shall notify the Director of Public Works in writing of the causes of delay within five (5) working days from the beginning of any such delay, and the Director shall ascertain the facts and the extent of the delay, and Director's findings of the facts thereon shall be final and conclusive.

If CONTRACTOR is delayed by reason of alterations made in these specifications, or by any act of the Director of Public Works or of the CITY, not contemplated by the contract, the time of completion shall be extended proportionately and CONTRACTOR shall be relieved during the period of such extension of any claim for liquidated damages, engineering or inspection charges or other penalties. CONTRACTOR shall have no claim for any other compensation for any such delay.

7. CONFORMANCE TO APPLICABLE LAWS. Contractor shall comply with all applicable Federal, State, and Municipal laws, rules and ordinances. Contractor shall not discriminate in the employment of persons or in the provision of services under this Contract on the basis of any legally protected classification, including race, color, national origin, ancestry, sex or religion of such person.

a. TITLE VI
Title VI of the Civil Rights Act of 1964 requires that “no person in the United States shall, on the grounds of race, color, or national origin, be excluded from participation in, be denied the benefits of, or be subjected to discrimination under any program or activity receiving federal financial assistance.” (42 USC Section 2000d)
http://www.dol.gov/oasam/regs/statutes/titlevi.htm.

Page 4 of 59 ends

731
Local Construction Contract – ABIDE BUILDERS, INC. – PROJECT NO. WP13270 (Updated 10/18/23) The City of Stockton requires compliance with the requirements of Title VI in all of its programs and activities regardless of funding source.

b. DISCRIMINATION AND HARASSMENT POLICY
The City of Stockton has a Discrimination and Harassment Policy (Exhibit C). The purpose of this policy is to reaffirm the CITY’s commitment to demonstrating respect for all individuals by strictly prohibiting discrimination and harassment, including sexual harassment in the workplace, to define the types of behavior and conduct prohibited by this policy, and to set forth a procedure for reporting, investigating, and resolving complaints of discrimination and harassment in the workplace.

c. LABOR STANDARDS PROVISIONS/CALIFORNIA LABOR CODE
The bidder shall understand that conditions set forth in Chapter 1, Part 7, Division 2 of the California Labor Code shall be considered part of the contract agreement.
https://leginfo.legislature.ca.gov/faces/codes_displayText.xhtml?lawCode= LAB&division=2.&title=&part=7.&chapter=1.&article=2.
d. PREVAILING WAGE

CONTRACTOR and any subcontractor shall pay each employee engaged in the trade or occupation not less than the prevailing hourly wage rate. In accordance with the provisions of Section 1770 of the Labor Code, the Director of Department of Industrial Relations of the State of California has determined the general prevailing rates of wages and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for in Section 1773.1, apprenticeship or other training programs authorized by Section 3093 and similar purposes applicable to the work to be done. CONTRACTOR performing the work under this contract shall obtain a copy of the wage rate determination and shall distribute copies to each subcontractor. As the wage determination for each craft reflects an expiration date, it shall be the prime CONTRACTOR and each subcontractor's responsibility to ensure that the prevailing wage rates of concern is current and paid to the employee.
i. The CONTRACTOR performing the work shall be responsible for obtaining a copy of the State wage rate determination. State wage rates may be obtained at
http://www.dir.ca.gov/OPRL/pwd/Determinations/Northern/Northern.p df. The CONTRACTOR shall be responsible for posting said wage rates at a prominent location at the work site and shall maintain same in a good readable condition for the duration of the work.

Page 5 of 59 ends

732
Local Construction Contract – ABIDE BUILDERS, INC. – PROJECT NO. WP13270 (Updated 10/18/23) ii. Should the CONTRACTOR choose to work on a Saturday, Sunday or on a holiday recognized by the Labor Unions, the CONTRACTOR shall reimburse the CITY the actual cost of engineering, inspection, superintendence, and or other overhead expenses which are directly chargeable to the contract. Should such work be undertaken at the request of the CITY, reimbursement will not be required. To conform strictly with the provisions of Division 2, Part 7, Chapter 1, Article 2, of the Labor Code of the State of California. To forfeit as a penalty to CITY the sum of TWENTY-FIVE AND NO/100 DOLLARS ($25.00) for each laborer, worker, or mechanic employed by CONTRACTOR, or by any subcontractor under CONTRACTOR, in the execution of this contract, for each calendar day during which any laborer, worker, or mechanic is required or permitted to work more than eight (8) hours and who is not paid the general prevailing rate of per diem wages for holiday and overtime work in violation of the provisions of Sections 1770 to 1781 of the Labor Code of the State of California. That all sums forfeited under the provisions of the foregoing sections shall be deducted from the payments to be made under the terms of this contract.
iii. The CONTRACTOR to whom the contract is awarded shall ensure that the prime and each subcontractor will in accordance with Section 1776 of the Labor Code, maintain certified payroll records. A copy of said records shall be provided with each invoice to the Public Works Department, Attention Contract Compliance Officer. It shall be the CONTRACTOR’S responsibility to obtain copies of the current prevailing wage rate determination for all subcontractors. Additionally, certified payroll records must be uploaded to the DIR website as required by labor code.
iv. The CONTRACTOR shall comply with the provisions established in Section 1777.5 of the Labor Code concerning the 1) certified approval by local joint apprenticeship committees for the employment and training of apprentices, and 2) contribution of funds to administer and conduct apprenticeship programs, if applicable to the job. e. LOCAL EMPLOYMENT ORDINANCE
Pursuant to Stockton Municipal Code Section 3.68.095 the CONTRACTOR and all subcontractors shall make a good faith effort to employ at least 50 percent of the workforce on this project from local residents, as measured by total labor work hours. Failure of any CONTRACTOR or subcontractor to comply with these requirements shall be deemed a material breach of the contract or subcontract. CONTRACTORS and subcontractors shall

Page 6 of 59 ends

733
Local Construction Contract – ABIDE BUILDERS, INC. – PROJECT NO. WP13270 (Updated 10/18/23) maintain records necessary for monitoring their compliance with section

3.68.095.
f. COMMUNITY WORKFORCE TRAINING AGREEMENT
Pursuant to the implementation of the Community Workforce Training Agreement (CWTA) adopted by the City Council on July 26, 2016, the successful bidder shall be required to comply with the provisions of CWTA. For any project subject to this Agreement, the Local Hire, Priority Apprentice and Workforce Development Program requirements shall apply in lieu of the requirements of Stockton Municipal Code Section 3.68.095 and no separate compliance with Section 3.68.095 will be required of the Contractors/Employers working on the project (EXHIBIT D). g. SANCTIONS
Deliverables must conform with all applicable federal, state, and local laws. Such conformity includes compliance with federal sanctions, and Contractor certifies that it has not and will not engage in prohibited transactions with sanctioned persons or entities.

CITY agrees:

8. COMPENSATION. To pay CONTRACTOR for the work herein
contemplated in the following manner: Progress payments will be made on or about the first day of each calendar month, in such sum as shall make the aggregate of payment up to such day equal to ninety-five percent (95%) of the proportional contract price, upon the basis of the progress certificate of the Director of Public Works as to the amount of work done and the proportional amount of the contract price represented therefore; and all of the remaining part of the contract price not as aforesaid paid, shall be paid at the expiration of thirty-five (35) days from the completion of said work of construction and the certification by the Director of Public Works of such completion.

9. SECURITIES. Pursuant to Section 22300 of the Public Contract Code, CONTRACTOR will be permitted, at its request and sole expense, to substitute securities for any monies withheld by the CITY to ensure performance under the contract. Said securities will be deposited either with the CITY or with a State or federally chartered bank as escrow agent. Securities eligible for this substitution are those listed in Section 16430 of the California Government Code or bank or savings and loan certificates of deposit.

CONTRACTOR shall be the beneficial owner of any securities substituted for monies withheld and shall receive any interest thereon.

Page 7 of 59 ends

734
Local Construction Contract – ABIDE BUILDERS, INC. – PROJECT NO. WP13270 (Updated 10/18/23)

10. CHANGE ORDERS. CITY reserves the right to make such alterations, deviations, additions to or omissions from the plans and specifications, including the right to increase or decrease the quantity of any item or portion of the work, as may be deemed by the Engineer to be necessary or advisable and to require such extra work as may be determined by the Engineer to be required for the proper completion or construction of the whole work contemplated.

Any such changes will be set forth in a contract change order which will specify, in addition to the work done in connection with the change made, adjustment of contract time, if any, and the basis of compensation for such work. A contract change order will not become effective until approved by the City Manager and/or the City Council.

Processing of change orders shall be in accordance with Section 4-1.05A of the City of Stockton Standard Specifications and Plans as adopted by Council on September 27, 2016, by Resolution No. 2016-09-27-1213, effective September 27, 2016, or as otherwise amended by Council. When the compensation for an item of work is subject to adjustment under the provisions of Standard Specifications and Plans, Section 4-1.05A, CONTRACTOR shall, upon request, promptly furnish the Engineer with adequate detailed cost data for such item of work.

11. AUDITS. CITY reserves the right to periodically audit all charges made by CONTRACTOR to CITY for services under the contract. Upon request, CONTRACTOR agrees to furnish CITY, or a designated representative, with necessary information and assistance.

CONTRACTOR agrees that CITY or its delegate will have the right to review, obtain and copy all records pertaining to performance of the contract. CONTRACTOR agrees to provide CITY or its delegate with any relevant information requested and shall permit CITY or its delegate access to its premises, upon reasonable notice, during normal business hours for the purpose of interviewing employees and inspecting and copying such books, records, accounts, and other material that may be relevant to a matter under investigation for the purpose of determining compliance with this requirement.

CONTRACTOR further agrees to maintain such records for a period of three (3) years after final payment under the contract.

12. WAIVER. It is expressly understood and agreed by and between the parties hereto that a waiver of any of the conditions of this contract shall not be considered a waiver of any of the other conditions thereof.

It is further understood and agreed by and between the parties hereto that time is of the essence of this contract in all respects.

Page 8 of 59 ends

735
EXHIBIT 2
736
EXHIBIT A Page 10 of 59 EXHIBIT 2 EXHIBIT 2
737
EXHIBIT A Page 11 of 59 EXHIBIT 2 EXHIBIT 2
738
EXHIBIT A Page 12 of 59 EXHIBIT 2 EXHIBIT 2
739
EXHIBIT A Page 13 of 59 EXHIBIT 2 EXHIBIT 2
740
EXHIBIT A Page 14 of 59 EXHIBIT 2 EXHIBIT 2
741
EXHIBIT A Page 15 of 59 EXHIBIT 2 EXHIBIT 2
742
REV 2025-06-04
Insurance Requirements for Construction Contracts
CANNERY PARK (2.7 ACRES)
Contractor shall procure and maintain for the duration of the contract, and for five (5) years thereafter, insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his agents, representatives, employees, or subcontractors.

MINIMUM SCOPE AND LIMIT OF INSURANCE
Coverage shall be at least as broad as:

1. Commercial General Liability (CGL): Insurance Services Office (ISO) Form CG 00 01 covering CGL on an “occurrence” basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $5,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit.

2. Automobile Liability: Insurance Services Office Form CA 0001 covering Code 1 (any auto), with limits no less than $3,000,000 per accident for bodily injury and property damage.

3. Workers’ Compensation insurance as required by the State of California, with Statutory Limits, and Employers’ Liability insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.

4. Professional Liability (Errors and Omissions) Insurance appropriates to the Consultant’s profession, with limits no less than $1,000,000 per occurrence or claim, and $1,000,000 policy aggregate.

5. Surety Bonds as described below.

If the contractor maintains broader coverage and/or higher limits than the minimums shown above, the City of Stockton requires and shall be entitled to the broader coverage and/or the higher limits maintained by the contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City of Stockton.

Self-Insured Retentions
Self-insured retentions must be declared to and approved by the City of Stockton. The City of Stockton may require the Contractor to purchase coverage with a lower EXHIBIT B Page 16 of 59 EXHIBIT 2 EXHIBIT 2
743
REV 2025-06-04
retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention. The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the named insured or City of Stockton. The CGL and any policies, including Excess liability policies, may not be subject to a self-insured retention (SIR) or deductible that exceeds $25,000 unless approved in writing by City of Stockton. Any and all deductibles and SIRs shall be the sole responsibility of Contractor or subcontractor who procured such insurance and shall not apply to the Indemnified Additional Insured Parties. City of Stockton may deduct from any amounts otherwise due Contractor to fund the SIR/deductible. Policies shall NOT contain any self-insured retention (SIR) provision that limits the satisfaction of the SIR to the Named Insured.

The policy must also provide that Defense costs, including the Allocated Loss Adjustment Expenses, will satisfy the SIR or deductible. City of Stockton reserves the right to obtain a copy of any policies and endorsements for verification.

Other Insurance Provisions
The insurance policies are to contain, or be endorsed to contain, the following provisions:

1. The City of Stockton, its officers, officials, employees, and volunteers are to be covered as additional insureds on the CGL policy with respect to liability arising out of work or operations performed by or on behalf of the Contractor including materials, parts, or equipment furnished in connection with such work or operations and automobiles owned, leased, hired, or borrowed by or on behalf of the Contractor.

General liability coverage can be provided in the form of an endorsement to the Contractor’s insurance (at least as broad as ISO Form CG 20 10 11 85 or both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 forms if later revisions used).

Additional insured Name of Organization shall read “City of Stockton, its officers, officials, employees, and volunteers.” Policy shall cover City of Stockton, its officers, officials, employees, and volunteers for all locations work is done under this contract.

2. For any claims related to this project, the Contractor’s insurance coverage shall be primary and non-contributory insurance coverage at least as broad as ISO CG 20 01 04 13 as respects the City of Stockton, its officers, officials, employees, and volunteers. Any insurance or self-insurance maintained by the City of Stockton, its officers, officials, employees, or volunteers shall be excess of the Contractor’s insurance and shall not contribute with it. This requirement shall also apply to any Excess or Umbrella liability policies. The City of Stockton does not accept endorsements limiting the Contractor’s insurance coverage to the sole negligence of the Named Insured.

3. Each insurance policy required by this clause shall provide that coverage shall not be canceled, except with notice to the City of Stockton.

EXHIBIT B Page 17 of 59 EXHIBIT 2 EXHIBIT 2
744
REV 2025-06-04
Claims Made Policies – (Professional & Pollution only)
If any coverage required is written on a claims-made coverage form:

1. The retroactive date must be shown, and this date must be before the execution date of the contract or the beginning of contract work.

2. Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of contract work.

3. If coverage is cancelled or non-renewed, and not replaced with another claimsmade policy form with a retroactive date prior to the contract effective, or start of work date, the Contractor must purchase extended reporting period coverage for a minimum of five (5) years after completion of contract work.

4. A copy of the claims reporting requirements must be submitted to the City of Stockton for review.

5. If the services involve lead-based paint or asbestos identification/remediation, the Contractors Pollution Liability policy shall not contain lead-based paint or asbestos exclusions. If the services involve mold identification/remediation, the Contractors Pollution Liability policy shall not contain a mold exclusion, and the definition of Pollution shall include microbial matter, including mold.

Umbrella or Excess Policies
The Contractor may use Umbrella or Excess Policies to provide the liability limits as required in this agreement. This form of insurance will be acceptable provided that all of the Primary and Umbrella or Excess Policies shall provide all of the insurance coverages herein required, including, but not limited to, primary and non-contributory, additional insured, Self-Insured Retentions (SIRs), indemnity, and defense requirements. The Umbrella or Excess policies shall be provided on a true “following form” or broader coverage basis, with coverage at least as broad as provided on the underlying Commercial General Liability insurance. No insurance policies maintained by the Additional Insureds, whether primary or excess, and which also apply to a loss covered hereunder, shall be called upon to contribute to a loss until the Contractor’s primary and excess liability policies are exhausted.

Acceptability of Insurers
Insurance is to be placed with insurers authorized to conduct business in the state with a current A.M. Best rating of no less than A: VII, unless otherwise acceptable to the City of Stockton.

Waiver of Subrogation
EXHIBIT B Page 18 of 59 EXHIBIT 2 EXHIBIT 2
745
REV 2025-06-04
Contractor hereby agrees to waive rights of subrogation which any insurer of Contractor may acquire from Contractor by virtue of the payment of any loss.

Contractor agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation. The Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of the City of Stockton for all work performed by the Contractor, its employees, agents and subcontractors.

Verification of Coverage
Contractor shall furnish the City of Stockton with original certificates and amendatory endorsements or copies of the applicable policy language effecting coverage required by this clause and a copy of the Declarations and Endorsements Pages of the CGL and any Excess policies listing all policy endorsements. All certificates and endorsements and copies of the Declarations & Endorsements pages are to be received and approved by the City of Stockton before work commences. However, failure to obtain the required documents prior to the work beginning shall not waive the Contractor’s obligation to provide them. The City of Stockton reserves the right to require complete, certified copies of all required insurance policies, including endorsements required by these specifications, at any time. City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances.

Subcontractors
Contractor shall require and verify that all subcontractors maintain insurance meeting all requirements stated herein, and Contractor shall ensure that City of Stockton is an additional insured on insurance required from subcontractors. For CGL coverage, subcontractors shall provide coverage with a form at least as broad as CG 20 38 04 13.

Duration of Coverage
CGL & Excess liability policies for any construction related work, including, but not limited to, maintenance, service, or repair work, shall continue coverage for a minimum of 5 years for Completed Operations liability coverage. Such Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of the contract of work.

Surety Bonds
Contractor shall provide the following Surety Bonds:

1. Bid Bond

2. Performance Bond

3. Payment Bond
EXHIBIT B Page 19 of 59 EXHIBIT 2 EXHIBIT 2
746
REV 2025-06-04

4. Maintenance Bond
The Payment Bond and the Performance Bond shall be in a sum equal to the contract price. If the Performance Bond provides for a one-year warranty a separate Maintenance Bond is not necessary. If the warranty period specified in the contract is for longer than one year a Maintenance Bond equal to 10% of the contract price is required. Bonds shall be duly executed by a responsible corporate surety, authorized to issue such bonds in the State of California and secured through an authorized agent with an office in California.

Special Risks or Circumstances
City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other circumstances.

Certificate Holder Address
The address for mailing certificates, endorsements and notices shall be:

City of Stockton
Its Officers, Officials, Employees and Volunteers
425 N El Dorado Street
Stockton, CA 95202
EXHIBIT B Page 20 of 59 EXHIBIT 2 EXHIBIT 2
747
EXHIBIT C Page 21 of 59 EXHIBIT 2 EXHIBIT 2
748
EXHIBIT C Page 22 of 59 EXHIBIT 2 EXHIBIT 2
749
EXHIBIT C Page 23 of 59 EXHIBIT 2 EXHIBIT 2
750
EXHIBIT C Page 24 of 59 EXHIBIT 2 EXHIBIT 2
751
EXHIBIT C Page 25 of 59 EXHIBIT 2 EXHIBIT 2
752
EXHIBIT C Page 26 of 59 EXHIBIT 2 EXHIBIT 2
753
EXHIBIT C Page 27 of 59 EXHIBIT 2 EXHIBIT 2
754
EXHIBIT C Page 28 of 59 EXHIBIT 2 EXHIBIT 2
755
EXHIBIT C Page 29 of 59 EXHIBIT 2 EXHIBIT 2
756
EXHIBIT C Page 30 of 59 EXHIBIT 2 EXHIBIT 2
757
EXHIBIT C Page 31 of 59 EXHIBIT 2 EXHIBIT 2
758
EXHIBIT C Page 32 of 59 EXHIBIT 2 EXHIBIT 2
759
EXHIBIT C Page 33 of 59 EXHIBIT 2 EXHIBIT 2
760
EXHIBIT C Page 34 of 59 EXHIBIT 2 EXHIBIT 2
761

Page 35 of 59 ends

762

Page 36 of 59 ends

763

Page 37 of 59 ends

764

Page 38 of 59 ends

765

Page 39 of 59 ends

766

Page 40 of 59 ends

767

Page 41 of 59 ends

768

Page 42 of 59 ends

769

Page 43 of 59 ends

770

Page 44 of 59 ends

771

Page 45 of 59 ends

772

Page 46 of 59 ends

773

Page 47 of 59 ends

774

Page 48 of 59 ends

775

Page 49 of 59 ends

776

Page 50 of 59 ends

777

Page 51 of 59 ends

778

Page 52 of 59 ends

779

Page 53 of 59 ends

780

Page 54 of 59 ends

781

Page 55 of 59 ends

782

BOND FOR FAITHFUL PERFORMANCE
KNOW ALL MEN BY THESE PRESENTS:

That we, __________________________________________________, a STATE OF CA CORPORATION, as Principal and
, a corporation, organized and existing under the laws
of the State of _ and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, as obligee, in the just and full sum of THREE MILLION AND NO/100 DOLLARS ($3,000,000), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to the said CITY, the said Principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.

The condition of the foregoing obligation is such that the above bounded Principal has simultaneously entered into a contract with the CITY, to do and perform the following work, to wit:

CANNERY PARK (2.7 ACRES)
(PROJECT NO. WP13270)
NOW, THEREFORE, if the above bounded Principal, CONTRACTOR, Company or
Corporation or its subcontractor, shall well and truly perform the work contracted to be done under said contract, then this obligation to be null and void; otherwise to remain in full force and effect.

No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract, or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY, and no forbearance on the part of the said CITY shall operate to relieve any Surety or Sureties from liability on this bond, and consent by said Surety is hereby given, and the said Surety hereby waives the

Page 56 of 59 ends

783
provisions of Sections 2819 and 2845 of the Civil Code of the State of California.

SIGNED AND SEALED on

APPROVED AS TO SURETY: By:

PRINCIPAL

SURETY
APPROVED AS TO FORM & CONTENT:

LORI M. ASUNCION

OFFICE OF THE CITY ATTORNEY
By:

ATTORNEY-IN-FACT
By:

DEPUTY CITY ATTORNEY

Page 57 of 59 ends

784
1 BOND FOR LABOR AND MATERIAL
KNOW ALL MEN BY THESE PRESENTS:

That we, _______________________________________________, a STATE OF CA CORPORATION, as Principal and , corporation,
organized and existing under the laws of the State of __________ and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, and unto any and all material suppliers, persons, companies, or corporations furnishing materials, provisions, provender or other supplies used in, upon, for or about the performance of the work contemplated to be executed or performed under the contract hereinafter mentioned, and all persons, companies, or corporations renting or hiring teams, or implements of machinery, for or contributing to said work and all persons who perform work or labor upon the same, and all persons who supply both work and materials, and whose claims have not been paid by the contractor, company or corporation in the just and full sum of THREE MILLION AND NO/100 DOLLARS ($3,000,000), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to said CITY and to said persons jointly and severally, the said principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.

The condition of the foregoing obligations is such that the above bounden Principal has simultaneously entered into a contract of even date herewith, with the CITY, to do and perform the following work, to-wit:

CANNERY PARK (2.7 ACRES)
PROJECT NO. WP13270
NOW, THEREFORE, if the above bounden Principal, CONTRACTOR, Company or Corporation or its subcontractor, fail to pay for all materials, provisions, provender, or other supplies, or teams, used in, upon, for or about the performance of the work contracted to be done, or for any work or labor done thereon of any kind, the Surety on

Page 58 of 59 ends

785
2 this bond will pay the same, in an amount not exceeding the sum specified in this bond, provided that any and all claims hereunder shall be filed and proceedings had in connection therewith as required by the provisions of Division 3, Part 4, Title 15, Chapter 5, Article 1 of the Civil Code of California, provided that in case suit is brought upon this bond, a reasonable attorney's fee shall be awarded by the Court to the prevailing party in said suit; said attorney's fee to be fixed as costs in said suit, and to be included in the judgment therein rendered.

No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY and no forbearance on the part of the said CITY shall operate to relieve any surety or sureties from liability on this bond, and consent to make such alterations without further notice to or consent by any such surety is hereby given, and the said sureties hereby waive the provisions of Sections 2819 and 2845 of the Civil Code of the State of California.

SIGNED AND SEALED on .

APPROVED AS TO SURETY: By:

PRINCIPAL

SURETY
APPROVED AS TO FORM & CONTENT:

LORI M. ASUNCION

OFFICE OF THE CITY ATTORNEY
By:

ATTORNEY-IN-FACT
By:

DEPUTY CITY ATTORNEY

Page 59 of 59 ends

786
City of Stockton
Legislation Text
File #: 25-1257, Version: 1

ADOPT RESOLUTION TO AUTHORIZE THE HARDING WAY LEFT-TURN POCKETS PROJECT

RECOMMENDATION
It is recommended that the City Council adopt a resolution to:

1. Appropriate State Highway Safety Improvement Program funds in the amount of $146,340 to the Harding Way Left-Turn Pockets, Project No. WT22046/State Project No. HSIPSL-5008 (195).

2. Appropriate $452,000 from the Public Facilities Fee Traffic Signal Fund Balance to the Harding Way Left-Turn Pockets, Project No. WT22046/State Project No. HSIPSL-5008(195).

3. Appropriate $260,167 from the Public Facilities Fee Air Quality Fund Balance to the Harding Way Left-Turn Pockets, Project No. WT22046/State Project No. HSIPSL-5008(195).

4. Approve the Notice of Exemption No. NOE50-24 under the California Environmental Quality Act for the Harding Way Left-Turn Pockets, Project No. WT22046/State Project No. HSIPSL5008(195).

5. Approve the plans and specifications for the Harding Way Left-Turn Pockets, Project No.

WT22046/State Project No. HSIPSL-5008(195).

6. Award a Construction Contract in the amount of $1,519,552 to Dirt Dynasty, Inc. of Farmington, CA, for the Harding Way Left-Turn Pockets, Project No. WT22046/State Project No. HSIPSL-5008(195).

It is also recommended that the City Manager be authorized to take appropriate and necessary actions to carry out the purpose and intent of this resolution.

Summary
The Harding Way Left-Turn Pockets project will install separate left-turn lanes, upgrade signals, and install high friction surface treatment at the intersections of Harding Way with Lincoln Street and with Pacific Avenue/Madison Avenue (Attachment A). The project was approved under the Highway Safety Improvement Program (HSIP) and was included in the 2021-26 Five-Year Capital Improvement Plan (CIP).

On September 18, 2025, the City received four bids for this project. The lowest bidder, Ray’s Electric, was deemed non-responsive. It is recommended that Council award a Construction Contract to the lowest responsive bidder, Dirt Dynasty, Inc., in the amount of $1,519,552. It is also recommended City of Stockton Page 1 of 3 Printed on 12/3/2025
powered by Legistar™787
File #: 25-1257, Version: 1
that Council adopt a resolution approving Notice of Exemption No. NOE50-24 under the California Environmental Quality Act (CEQA), approving the plans and specifications, and appropriating funds for the project.

Construction is anticipated to begin in spring 2026 and be completed by fall 2026, weather permitting.

DISCUSSION
Background
The HSIP is a core federal-aid program established to achieve a significant reduction in traffic fatalities and serious injuries on all public roads. Caltrans, Division of Local Assistance, manages California’s local agency share of HSIP funds. HSIP focuses on infrastructure projects with nationally recognized crash reduction factors. Local HSIP projects are prioritized based on crash experience, benefit from counter measures, or other data-supported means.

In October 2020, the City submitted nine grant applications to Caltrans for Cycle 10 of the HSIP grant program, including the Harding Way Left-Turn Pockets project.

The Harding Way Left-Turn Pockets project will install separate left-turn lanes, upgrade signals, and install high friction surface treatment at the intersections of Harding Way with Lincoln Street and with Pacific Avenue/Madison Avenue. These identified safety improvement measures will reduce left-turn conflicts and enhance visibility. The project was included in the 2021-26 Five-Year CIP.

In March 2021, the Harding Way Left-Turn Pockets, Project No. WT22046/State Project No. HSIPSL5008(195), was approved for HSIP funding for design and construction. In January 2022, the City received approval from the State to commence design work. In June 2025, the City received approval to commence the construction process. This project is 90 percent State funded. A 10 percent local match is required as part of the grant.

On July 26, 2016, Council adopted a Community Workforce and Training Agreement (CWTA). The CWTA became effective August 25, 2016, and applies to all Public Works projects over $1 million that are bid after that date. On July 16, 2019, by Motion No. 2019-07-16-1403, Council extended the CWTA term to August 25, 2024. On August 20, 2024, by Motion No. 2024-08-20-1203, Council extended the CWTA term to August 25, 2029. The CWTA was applied to this project as the estimated construction cost was over $1 million.

Present Situation
On August 21, 2025, the Harding Way Left-Turn Pockets, Project No. WT22046/State Project No.

HSIPSL-5008(195), was advertised for bids. On September 18, 2025, four bids were received with the following results:

COMPANY NAME BID AMOUNT
Ray’s Electric (Oakland, CA) $1,442,868.35
Dirt Dynasty, Inc. (Farmington, CA) $1,519,552.00
B&M Builders, Inc. (Rancho Cordova, CA) $1,567,785.00
City of Stockton Page 2 of 3 Printed on 12/3/2025
powered by Legistar™788
File #: 25-1257, Version: 1
FBD Vanguard Construction, Inc. (Livermore, CA) $1,584,763.00 Engineer’s Estimate $1,640,485.00
State and federal funding programs prohibit the use of the Local Employment Ordinance, Stockton Municipal Code (SMC) section 3.68.095, and the Local Business Preference Ordinance, SMC section 3.68.090.

Public Works’ staff, with the assistance of the City Attorney’s Office, reviewed the bid from the lowest bidder, Ray’s Electric, and determined that the bid was non-responsive based on the requirements of Caltrans’ Local Assistance Procedures Manual, Section 15.5.1. Specifically, their bid price for Bid Item No. 25 - micro surface high friction surface treatment - was more than 70 percent different than all other bidders, making it mathematically and materially unbalanced. Given the mathematical and material unbalance for Bid Item No. 25, the bid as presented by Ray’s Electric would not represent the lowest ultimate cost to the City. Ray’s Electric was notified of this determination by letter dated October 7, 2025.

The bid from Dirt Dynasty, Inc., the lowest responsive bidder, is regular in all respects. It is recommended that Council approve the plans and specifications, and award a Construction Contract to Dirt Dynasty, Inc. of Farmington, CA, in the amount of $1,519,552, for the Harding Way Left-Turn Pockets, Project No. WT22046/State Project No. HSIPSL-5008(195).

The project is in conformance with the City’s General Plan, pursuant to California Government Code, section 65402, and is categorically exempt from the requirements of CEQA as specified under Section 15302 of the CEQA Guidelines. The activities related to this project constitute a discretionary project under the City’s jurisdiction and qualifies as a project that does not have a significant effect on the environment. The resolution will approve the filing of Notice of Exemption No. NOE50-24 under CEQA. Construction is anticipated to begin in spring 2026 and be completed by fall 2026, weather permitting.

FINANCIAL SUMMARY
With the appropriation of funds to the Harding Way Left-Turn Pockets, Project No. WT22046/State Project No. HSIPSL-5008(195), there will be sufficient funds to award a Construction Contract in the amount of $1,519,552 to Dirt Dynasty, Inc.

There is no impact to the City’s General Fund or any other unrestricted fund as a result of taking the recommended actions.

Attachment A - Vicinity Map
City of Stockton Page 3 of 3 Printed on 12/3/2025
powered by Legistar™789
790
Resolution No.

STOCKTON CITY COUNCIL

RESOLUTION APPROPRIATING FUNDS, APPROVING THE NOTICE OF EXEMPTION NO. NOE50-24, APPROVING THE PLANS AND SPECIFICATIONS, AND

AWARDING A CONSTRUCTION CONTRACT FOR THE HARDING WAY LEFT-TURN POCKETS, PROJECT NO. WT22046/STATE PROJECT NO. HSIPSL-5008(195) On September 18, 2025, the City Clerk of the City of Stockton opened, examined, and publicly declared the sealed proposals or bids offered for the Harding Way Left-Turn Pockets, Project No. WT22046/State Project No. HSIPSL-5008(195); and The project will install separate left-turn lanes, upgrade signals, and install high friction surface treatment at the intersections of Harding Way with Lincoln Street and with Pacific Avenue/Madison Avenue; and
Dirt Dynasty, Inc. is the lowest responsive bidder in the amount of $1,519,552 and its bid is regular in all respects; and
The project is in conformance with the City’s General Plan, pursuant to California Government Code, section 65402, and is categorically exempt from the requirements of the California Environmental Quality Act (CEQA) as specified under section 15302 of the CEQA Guidelines, because this is a discretionary project under the City’s jurisdiction and qualifies as a project which has been determined to not have a significant effect on the environment; now, therefore,

BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF STOCKTON, AS FOLLOWS:

1. The City Council authorizes the appropriation of State Highway Safety Improvement Program funds in the amount of $146,340 to the Harding Way Left-Turn Pockets, Project No. WT22046/State Project No. HSIPSL-5008(195).

2. The City Council authorizes the appropriation of Public Facilities Fee Traffic Signal funds in the amount of $452,000 to the Harding Way Left-Turn Pockets, Project No. WT22046/State Project No. HSIPSL-5008(195).

3. The City Council authorizes the appropriation of Public Facilities Fee Air Quality funds in the amount of $260,167 to the Harding Way Left-Turn Pockets, Project No. WT22046/State Project No. HSIPSL-5008(195).

4. The City Council approves the filing of Notice of Exemption No. NOE50-24 under the CEQA for the Harding Way Left-Turn Pockets, Project No. WT22046/State 791
Project No. HSIPSL-5008(195), a copy of which is attached as Exhibit 1 and incorporated by this reference.

5. The City Council approves the plans and specifications for the Harding Way Left-Turn Pockets, Project No. WT22046/State Project No. HSIPSL-5008(195).

6. The City Council awards a Construction Contract between the City of Stockton and Dirt Dynasty, Inc., in the amount of $1,519,552, and the City Manager is authorized and directed to execute same, a copy of which is attached as Exhibit 2 and incorporated by this reference.

7. The City Manager is hereby authorized to take whatever actions are necessary and appropriate to carry out the purpose and intent of this Resolution.

PASSED, APPROVED, and ADOPTED December 9, 2025 .

CHRISTINA FUGAZI
Mayor of the City of Stockton
ATTEST:

KATHERINE ROLAND, CMC, CPMC
City Clerk of the City of Stockton
792
793
State-Aid Construction Contract – DIRT DYNASTY, INC.– PROJECT NO. WT22046/HSIPSL-5008(195) (Updated 10/18/23)

CONSTRUCTION CONTRACT
This contract is made and entered into on _____________, by and between DIRT DYNASTY, INC., a STATE OF CA CORPORATION, with a business address at P.O.

BOX 67, FARMINGTON, CA 95320, hereinafter called "CONTRACTOR," and CITY OF STOCKTON, a municipal corporation, hereinafter called "CITY." W I T N E S S E T H:

WHEREAS, plans and specifications for the construction of HARDING WAY LEFT-TURN POCKETS, PROJECT NO. WT22046/STATE PROJECT NO. HSIPSL5008(195), hereinafter called “PROJECT,” were regularly adopted by Council Resolution No. __________________, on _________________; and WHEREAS, the contract for said work was regularly awarded to CONTRACTOR, by Council Resolution No. __________________, on ________________.

NOW, THEREFORE, in consideration of the promises and of the mutual covenants herein contained, the parties hereto expressly agree as follows:

CONTRACTOR agrees:

1. SCOPE OF SERVICES. To do the work and furnish all the labor, materials, tools, equipment, and insurance required for the construction of PROJECT in accordance with the plans and specifications adopted on _____________, by Council Resolution No. __________________. The "contract documents," which include the bid documents, project plans, specifications, all letters of clarification, and the City of Stockton Standard Specifications and Plans, are incorporated into and made a part of this contract by this reference to the same extent as if fully set forth.

2. COMPENSATION. To do and perform the work contemplated hereby in a good and workmanlike manner and to furnish all labor, materials, tools, and equipment necessary therefore at the prices specified in Exhibit A, attached hereto and by reference made a part hereof, under the direction of and to the complete satisfaction of the Director of Public Works of the City of Stockton. Total compensation for services and reimbursement for costs shall not exceed $1,519,552, or as otherwise mutually agreed to in a Contract Change Order.

3. INSURANCE. CONTRACTOR shall not commence any work before obtaining, and shall maintain in force at all times during the duration and performance of this contract, the policies of insurance specified in Exhibit B, which is attached to this contract and incorporated by this reference, and as provided in the “contract documents” including Section 7-1.06 of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27-1213, effective September 27, 2016.

Page 1 of 123 ends

794
State-Aid Construction Contract – DIRT DYNASTY, INC.– PROJECT NO. WT22046/HSIPSL-5008(195) (Updated 10/18/23)
It shall be a requirement under this Agreement that any available insurance proceeds broader than or in excess of the specified minimum Insurance coverage requirements and/or limits shall be available to the Additional Insured.

Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any Insurance policy or proceeds available to the named Insured; whichever is greater.

The Additional Insured coverage under the Contractor’s policy shall be “primary and noncontributory” and will not seek contribution from the City of Stockton’s insurance or selfinsurance and shall be at least as broad as CG 20 01 04 13.

The limits of insurance required in this Agreement may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess Insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis for the benefit of the City of Stockton (if agreed to in a written contract or Agreement) before the City of Stockton’s own insurance or selfinsurance shall be called upon to protect it as a named insured.

All self-insured retentions (SIR) must be disclosed to Risk Management for approval and shall not reduce the limits of liability. Payment Bond in the amount of the self-insured retention (SIR) may be required.

Policies containing any self-insured retention (SIR) provision shall provide or be endorsed to provide that the SIR may be satisfied by either the named Insured or the City of Stockton.

The City of Stockton reserves the right to obtain a full certified copy of any Insurance policy and endorsements.

Failure to exercise this right shall not constitute a waiver of right to exercise later.

Contractor shall maintain insurance as required by this contract to the fullest amount allowed by law and shall maintain insurance for a minimum of five years following the completion of this project. In the event contractor fails to obtain or maintain completed operations coverage as required by this Agreement, the City at its sole discretion may purchase the coverage required and the cost will be paid by contractor.

Contractor agrees to include with all Subcontractors in their subcontract the same requirements and provisions of this Agreement including the indemnity and insurance requirements to the extent they apply to the scope of the Subcontractor’s work.

Subcontractors hired by Contractor agree to be bound to Contractor and the City of Stockton in the same manner and to the same extent as Contractor is bound to the City of Stockton under the Contract Documents. Subcontractor further agrees to include these same provisions with any Sub-subcontractor. A copy of the City of Stockton Contract

Page 2 of 123 ends

795
State-Aid Construction Contract – DIRT DYNASTY, INC.– PROJECT NO. WT22046/HSIPSL-5008(195) (Updated 10/18/23)
Document Indemnity and Insurance provisions will be furnished to the Subcontractor upon request. The General Contractor shall require all sub-contractors to provide a valid certificate of insurance and the required endorsements included in the Agreement prior to commencement of any work and contractor will provide proof of compliance to the City.

4. INDEMNITY AND HOLD HARMLESS. To the fullest extent permitted by law, Contractor shall hold harmless, defend, and indemnify City of Stockton and its officers, officials, employees, and volunteers from and against all claims, damages, losses, and expenses including attorney fees arising out of the performance of the work described herein, caused in whole or in part by any negligent act or omission of the Contractor, any subcontractor, anyone directly or indirectly employed by any of them, or anyone for whose acts any of them may be liable, except where caused by the active negligence, sole negligence, or willful misconduct of the City of Stockton. This obligation is independent of, and shall not in any way be limited by, the minimum Insurance obligations contained in this agreement. These obligations shall survive the completion or termination of this agreement.

5. STANDARD PLANS AND SPECIFICATIONS. The performance of said work and the furnishing of said materials shall be executed in accordance with Section 8-1.04B of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27-1213, effective September 27, 2016, and the provisions of the issued project specifications.

The Director of Public Works will furnish CONTRACTOR a weekly statement showing the number of days charged to the contract for the preceding week, the number of days specified for completion of the contract, and the number of days remaining to complete the contract. CONTRACTOR will be allowed one (1) week in which to file a written protest setting forth in what respects said weekly statement is incorrect, otherwise the statement shall be deemed to have been accepted by CONTRACTOR as correct.

6. WORKING DAYS. It is agreed by the parties to the contract that in case all the work called for under the contract in all parts and requirements, is not finished or completed within the number of days as set forth, damage will be sustained by CITY, and that it is and will be impracticable and extremely difficult to ascertain the actual damage which CITY will sustain in the event of and by reason of such delay; and it is therefore agreed that CONTRACTOR will pay to CITY the sum of FOUR THOUSAND TWO HUNDRED AND NO/100 DOLLARS ($4200) per day for each and every calendar day's delay in finishing the work in excess of the number of days prescribed; and CONTRACTOR agrees to pay said liquidated damages as herein provided, and in case the same are not paid, agrees that CITY, may deduct the amount thereof from any monies due or that may become due CONTRACTOR under the contract.

It is further agreed that in case the work called for under the contract is not finished and completed in all parts and requirements within the number of days as specified, CITY shall have the right to increase the number of days or not, as may seem best to serve the interest of CITY, and if CITY decides to increase the said number of days, CITY shall

Page 3 of 123 ends

796
State-Aid Construction Contract – DIRT DYNASTY, INC.– PROJECT NO. WT22046/HSIPSL-5008(195) (Updated 10/18/23)
further have the right to charge to CONTRACTOR, CONTRACTOR's heirs, assigns or sureties, and to deduct from the final payment for the work, all or any part, as may be deemed proper, the liquidated damages as specified or the actual cost of engineering, inspection, superintendence, and other overhead expenses which are directly chargeable to the contract, and which accrue during the period of such extension, whichever is greater, except the cost of final surveys and preparation of final estimate shall not be included in such charges.

A working day shall not include, nor shall CONTRACTOR be assessed with liquidated damages nor the additional cost of engineering and inspection during any delay beyond the time named for the completion of the work caused by acts of God or of the public enemy, acts of CITY, fire, floods, epidemics, quarantine restrictions, strikes, and freight embargoes and subject to approval by the Director, inability to get materials ordered by CONTRACTOR or Subcontractor due to such causes provided that CONTRACTOR shall notify the Director in writing of the causes of delay within five (5) working days from the beginning of any such delay, and the Director shall ascertain the facts and the extent of the delay, and Director's findings of the facts thereon shall be final and conclusive.

If CONTRACTOR is delayed by reason of alterations made in these specifications, or by any act of the Director or of CITY, not contemplated by the contract, the time of completion shall be extended proportionately and CONTRACTOR shall be relieved during the period of such extension of any claim for liquidated damages, engineering or inspection charges or other penalties. CONTRACTOR shall have no claim for any other compensation for any such delay.

7. CONFORMANCE TO APPLICABLE LAWS

A. TITLE VI
Title VI of the Civil Rights Act of 1964 requires that “no person in the United States shall, on the grounds of race, color, or national origin, be excluded from participation in, be denied the benefits of, or be subjected to discrimination under any program or activity receiving federal financial assistance.” (42 USC Section 2000d)
http://www.dol.gov/oasam/regs/statutes/titlevi.htm.

The City of Stockton requires compliance with the requirements of Title VI in all of its programs and activities regardless of funding source.

B. DISCRIMINATION AND HARASSMENT POLICY
The City of Stockton has a Discrimination and Harassment Policy (Exhibit C). The purpose of this policy is to reaffirm the CITY’s commitment to demonstrating respect for all individuals by strictly prohibiting discrimination and harassment, including sexual harassment in the workplace, to define

Page 4 of 123 ends

797
State-Aid Construction Contract – DIRT DYNASTY, INC.– PROJECT NO. WT22046/HSIPSL-5008(195) (Updated 10/18/23)
the types of behavior and conduct prohibited by this policy, and to set forth a procedure for reporting, investigating, and resolving complaints of discrimination and harassment in the workplace.

C. LABOR STANDARDS AND PROVISIONS/CALIFORNIA LABOR CODE The bidder shall understand that conditions set forth in Chapter 1, Part 7, Division 2 of the California Labor Code shall be considered part of the contract agreement.
https://leginfo.legislature.ca.gov/faces/codes_displayText.xhtml?lawCode= LAB&division=2.&title=&part=7.&chapter=1.&article=2.

D. PREVAILING WAGE
CONTRACTOR and any Subcontractor shall pay each employee engaged in the trade or occupation not less than the prevailing hourly wage rate. In accordance with the provisions of Section 1770 of the Labor Code, the Director of Department of Industrial Relations of the State of California has determined the general prevailing rates of wages and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for in Section 1773.1, apprenticeship or other training programs authorized by Section 3093 and similar purposes applicable to the work to be done. CONTRACTOR performing the work under this contract shall obtain a copy of the wage rate determination and shall distribute copies to each Subcontractor (see Exhibit D). As the wage determination for each craft reflects an expiration date, it shall be the prime CONTRACTOR and each Subcontractor's responsibility to ensure that the prevailing wage rates of concern is current and paid to the employee.
(i) The CONTRACTOR performing the work shall be responsible for obtaining a copy of the State wage rate determination. State wage rates may be obtained at
http://www.dir.ca.gov/OPRL/pwd/Determinations/Northern/Northern.p df. The CONTRACTOR shall be responsible for posting said wage rates at a prominent location at the work site and shall maintain same in a good readable condition for the duration of the work. (ii) Should the CONTRACTOR choose to work on a Saturday, Sunday or on a holiday recognized by the Labor Unions, the CONTRACTOR shall reimburse the CITY the actual cost of engineering, inspection, superintendence, and or other overhead expenses which are directly chargeable to the contract. Should such work be undertaken at the request of the CITY, reimbursement will not be required. To conform strictly with the provisions of Division 2, Part 7, Chapter 1, Article 2, of the Labor Code of the State of California. To forfeit as a penalty to CITY the sum of TWENTY-FIVE AND NO/100 DOLLARS ($25.00) for

Page 5 of 123 ends

798
State-Aid Construction Contract – DIRT DYNASTY, INC.– PROJECT NO. WT22046/HSIPSL-5008(195) (Updated 10/18/23)
each laborer, worker, or mechanic employed by CONTRACTOR, or by any Subcontractor under CONTRACTOR, in the execution of this contract, for each calendar day during which any laborer, worker, or mechanic is required or permitted to work more than eight (8) hours and who is not paid the general prevailing rate of per diem wages for holiday and overtime work in violation of the provisions of Sections 1770 to 1781 of the Labor Code of the State of California. That all sums forfeited under the provisions of the foregoing sections shall be deducted from the payments to be made under the terms of this contract.

(iii) The CONTRACTOR to whom the contract is awarded shall ensure that the prime and each subcontractor will in accordance with Section 1776 of the Labor Code, maintain certified payroll records. A copy of said records shall be provided with each invoice to the Public Works Department, Attention Contract Compliance Officer. It shall be the CONTRACTOR’S responsibility to obtain copies of the current prevailing wage rate determination for all subcontractors. Additionally, certified payroll records must be uploaded to the DIR website as required by labor code.

(iv) The CONTRACTOR shall comply with the provisions established in Section 1777.5 of the Labor Code concerning the 1) certified approval by local joint apprenticeship committees for the employment and training of apprentices, and 2) contribution of funds to administer and conduct apprenticeship programs, if applicable to the job.

E. APPENDIX E OF THE TITLE VI ASSURANCES

During the performance of this contract, the contractor, for itself, its assignees, and successors in interest agrees to comply with the Appendix E of the Title VI Assurances attached as Exhibit E.

F. COMMUNITY WORKFORCE TRAINING AGREEMENT
Pursuant to the implementation of the Community Workforce Training Agreement (CWTA) adopted by the City Council on July 26, 2016, the successful bidder shall be required to comply with the provisions of CWTA. For any project subject to this Agreement, the Local Hire, Priority Apprentice and Workforce Development Program requirements shall apply in lieu of the requirements of Stockton Municipal Code Section 3.68.095 and no separate compliance with Section 3.68.095 will be required of the Contractors/Employers working on the project (EXHIBIT F).

Page 6 of 123 ends

799
State-Aid Construction Contract – DIRT DYNASTY, INC.– PROJECT NO. WT22046/HSIPSL-5008(195) (Updated 10/18/23)
G. SANCTIONS
Deliverables must conform with all applicable federal, state, and local laws. Such conformity includes compliance with federal sanctions, and Contractor certifies that it has not and will not engage in prohibited transactions with sanctioned persons or entities.

CITY agrees:

CONTRACTOR shall be the beneficial owner of any securities substituted for monies withheld and shall receive any interest thereon.

Processing of change orders shall be in accordance with Section 4-1.05A of the City of Stockton Standard Specifications and Plans as adopted by Council on September 27, 2016, by Resolution No. 2016-09-27-2013, effective September 27, 2016, or as otherwise amended by Council. When the compensation for an item of work is subject to adjustment under the provisions of Standard Specifications and Plans, Section 4-1.05A,

Page 7 of 123 ends

800
CONTRACTOR shall, upon request, promptly furnish the Engineer with adequate detailed cost data for such item of work.

11. AUDITS
(a) CITY reserves the right to periodically audit all charges made by CONTRACTOR to CITY for services under the contract. Upon request, CONTRACTOR agrees to furnish CITY, or a designated representative, with necessary information and assistance.
(b) CONTRACTOR agrees that CITY or its delegate will have the right to review, obtain and copy all records pertaining to performance of the contract.

CONTRACTOR agrees to provide CITY or its delegate with any relevant information requested and shall permit CITY or its delegate access to its premises, upon reasonable notice, during normal business hours for the purpose of interviewing employees and inspecting and copying such books, records, accounts, and other material that may be relevant to a matter under investigation for the purpose of determining compliance with this requirement. CONTRACTOR further agrees to maintain such records for a period of five (5) years after final payment under the contract.

It is further understood and agreed by and between the parties hereto that time is of the essence of this contract in all respects.

IN WITNESS WHEREOF, the parties hereto have hereunto affixed their hands and seals the day and year first above written.

ATTEST:

KATHERINE ROLAND, CMC, CPMC

CITY CLERK
By: ____________ _
APPROVED AS TO FORM & CONTENT:

LORI M. ASUNCION

OFFICE OF THE CITY ATTORNEY
By:-------------

DEPUTY CITY ATTORNEY
By: ____________ _

JOHNNY FORD

CITY MANAGER
By: / }Jn,DIRT ltDYNASTY, INC.

Stephen McPeak, Secretary/Treasurer
46-5704806
Tax Identification No.

State-Aid Construction Contract- DIRT DYNASTY, INC.- PROJECT NO. Wf22046/HSIPSL-5008(195) (Updated 10/18/23)

Page 8 of 123 ends

EXHIBIT 2
801
EXHIBIT A Page 9 of 123 EXHIBIT 2
802
EXHIBIT A Page 10 of 123 EXHIBIT 2
803
REV 2025-06-04
Insurance Requirements for Construction Contracts
Harding Way Left-Turn Pockets, Project No. WT22046
State Project No. HSIPSL-5008 (195)
Contractor shall procure and maintain for the duration of the contract, and for five (5) years thereafter, insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his agents, representatives, employees, or subcontractors.

MINIMUM SCOPE AND LIMIT OF INSURANCE
Coverage shall be at least as broad as:

2. Automobile Liability: Insurance Services Office Form CA 0001 covering Code 1 (any auto), with limits no less than $5,000,000 per accident for bodily injury and property damage.

4. Professional Liability (Errors and Omissions) Insurance appropriates to the Consultant’s profession, with limits no less than $2,000,000 per occurrence or claim, and $2,000,000 policy aggregate.

5. Surety Bonds as described below.

Self-Insured Retentions
EXHIBIT B Page 11 of 123 EXHIBIT 2
804
REV 2025-06-04
Self-insured retentions must be declared to and approved by the City of Stockton. The City of Stockton may require the Contractor to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention. The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the named insured or City of Stockton. The CGL and any policies, including Excess liability policies, may not be subject to a self-insured retention (SIR) or deductible that exceeds $25,000 unless approved in writing by City of Stockton. Any and all deductibles and SIRs shall be the sole responsibility of Contractor or subcontractor who procured such insurance and shall not apply to the Indemnified Additional Insured Parties. City of Stockton may deduct from any amounts otherwise due Contractor to fund the SIR/deductible. Policies shall NOT contain any self-insured retention (SIR) provision that limits the satisfaction of the SIR to the Named Insured.

Other Insurance Provisions
The insurance policies are to contain, or be endorsed to contain, the following provisions:

EXHIBIT B Page 12 of 123 EXHIBIT 2
805
REV 2025-06-04

3. Each insurance policy required by this clause shall provide that coverage shall not be canceled, except with notice to the City of Stockton.

Claims Made Policies – (Professional & Pollution only)
If any coverage required is written on a claims-made coverage form:

1. The retroactive date must be shown, and this date must be before the execution date of the contract or the beginning of contract work.

2. Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of contract work.

4. A copy of the claims reporting requirements must be submitted to the City of Stockton for review.

EXHIBIT B Page 13 of 123 EXHIBIT 2
806
REV 2025-06-04
Waiver of Subrogation
Contractor hereby agrees to waive rights of subrogation which any insurer of Contractor may acquire from Contractor by virtue of the payment of any loss.

Surety Bonds
Contractor shall provide the following Surety Bonds:

1. Bid Bond

2. Performance Bond
EXHIBIT B Page 14 of 123 EXHIBIT 2
807
REV 2025-06-04

3. Payment Bond

Certificate Holder Address
The address for mailing certificates, endorsements and notices shall be:

City of Stockton
Its Officers, Officials, Employees and Volunteers
425 N El Dorado Street
Stockton, CA 95202
EXHIBIT B Page 15 of 123 EXHIBIT 2
808
EXHIBIT C Page 16 of 123 EXHIBIT 2
809
EXHIBIT C Page 17 of 123 EXHIBIT 2
810
EXHIBIT C Page 18 of 123 EXHIBIT 2
811
EXHIBIT C Page 19 of 123 EXHIBIT 2
812
EXHIBIT C Page 20 of 123 EXHIBIT 2
813
EXHIBIT C Page 21 of 123 EXHIBIT 2
814
EXHIBIT C Page 22 of 123 EXHIBIT 2
815
EXHIBIT C Page 23 of 123 EXHIBIT 2
816
EXHIBIT C Page 24 of 123 EXHIBIT 2
817
EXHIBIT C Page 25 of 123 EXHIBIT 2
818
EXHIBIT C Page 26 of 123 EXHIBIT 2
819
EXHIBIT C Page 27 of 123 EXHIBIT 2
820
EXHIBIT C Page 28 of 123 EXHIBIT 2
821
EXHIBIT C Page 29 of 123 EXHIBIT 2
822

!!
"

!
!

#$

%

&'()$*()$ &
&+ (
&,-$
!

')
'
!

!'.

'/
&
' 0'0

'0
'0
!$'
%
!
'
.

'
1
2
'
0!
'
!'
!3'
!

#

!

"

4 %567 68
#95#68:981;#
< 9; 6:981;#
*

!

,

&-
=+<(;>?8
#95#68:981;#
*

!

-!-

&+<(6(@?8
#95#68:981;#

!
!
!

A
!!
!, )

!&$ 2
!

$!
!!,

-&! 2
;C
!
)8

;C
!
)8D
4 :

!!,!!,
;C
!
)8

)

!
!
!
!
$!,"&
)!!,!
A
!!
!, )

!
!
"'!

!

!
!

A
!
$!
!, )

9!
!
'

&!,

!"
!,!.94*+*+4 EEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEE F6"!,

!
!

!F4;C
!
)8
F F
!

"!1$D'F&$

!
!,F F'
!,

!
!

!
!4F F-
C!*4&4'F4#,

!
!

!
$F F

+

F

)-
=
!F F"!1$D'F
!GH4H
,
*
F FF!,

-&!F F

!
!,

-&F F!
!

'
"
!

F F,
&,+"
,

F F

!
"

&
!,F F

!
!
4F FEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEFEEEEEEEEEEEEEEEEEEEEEEEEEEEEEF F6"!,

!
!-
-
F4;C
!
)8D
F F
!-1$'F&$

!
!,F F1$''!,F

!
!4F F

!
!

!-
F4#,

!
!

!
$F FC!

"!1$F

)-
=
!
!F FD'FGD4D
,
*
!,F FF

-&!

!F F
!,

-&!
!

'F F
"
!

,
&,+"
F F,

!
"

&
F F!,!

!
!
4F FEEEEEEEEEEEEEEEEEEEEEEEEEEEEEEFEEEEEEEEEEEEEEEEEEEEEEEEEEEEEF #,

;C
!
)8

-&!-
A
!$46"!,

!
!

)$

"!, ;C
!
)8

$"

"

"-
=
!,

!
!

!

-&!
!

'!,

!
!

!
!

!

"

2
!4
!

"
!

!
!
2
!
-
=

!
!

!,;C
!
)8

)
! ,!!
---4
4&
)-,&
)

!
!
4 0

! EXHIBIT D Page 30 of 123 EXHIBIT 2
823

! "#
"$%&
"&'"
&( "&&"
""
"(" &"
)*+,-./0+, ,1+,*2,+324)5
62-7+-8)9)-:2;,3)*+-.)5 8)/:5+-<
/=5;:+, >-+>)-)*.2/6+**./0 ,*-.>>./0-+324)5 ,=-)>>./04)=;;3./01)00./0 )/::.,>2,./02?)55 ./,;5)*.2/3)*+-.)5,?-23 3+=8)/.=)5,@,*+3,68+*8+- *8+@=2/*)./),1+,*2,2-/2*A -+)BBBBBBBBBBBBBBBBBBBBBBC B B -+)BBBBBBBBBBBBBBBBBBBBBBC BB
"""#
"
""("&' &

! $%&
"
&("&& )*+,-./0+, ,1+,*2,D2-7+-,
/,;5)*2- <
/=5;:+,*8+)>>5.=)*.2/2? )55./,;5)*./03)*+-.)5, !-2*+=*.4+24+-./0, 2)*./0,)/:./.,8+,*2)55 *@>+,2?3+=8)/.=)5,@,*+3,A -+)BBBBBBBBBBBBBBBBBBBBBBC B
B -+)BBBBBBBBBBBBBBBBBBBBBBC
B
B
""
"(" &"
EXHIBIT D Page 31 of 123 EXHIBIT 2
824

#
!$%&
'''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''' $$$%'$$
$&($
($ )

&$ '''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''' $$$%'$$%$&($
($

"%$
%
'''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''' $$$%'$$#$#($
($ * +
,-.. /.0-.1/

"#
&$ +",11-. -

#"
$&
#$ +&,23/.
-
-.-.
2

#!
!
& + ,
24. 5-67.27. -7273

#
"!#
$
+
!,-8.
79

&"
& '''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''' $$$%'$$&$"($
($ ::
)

%$
& ::
;
(

!$
#&
" '''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''' $$$%'$

$($
($
23/.
-
-.-8.-. 11-.-. 2.
79
24.5-67.27.7-273 %-../.0-.1/ )

%"
"#

%
"!

%
!&
&
% 28

#

!

"
# %

#$
&
$# '''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''' <$$'$$
$"($
($% 11-
-78 EXHIBIT D Page 32 of 123 EXHIBIT 2
825

"! #
!!$%%& !!

'$ !
(

)
*

+
(

,, ---------------------------------------------------------------- ."(-,/,

,

0 1 .
2
#3 2
2$
$

(,(
0 1
4
,(
0 12

,(
0 1,
(
+
%#
5* 6
7(
,(
5!
47

,(
0'"2".85!%$0 1

79
,%

% ,,,
%
% ,
,

%(
%

,%-

% !.2:.2;#<0;3;<=9 2
4

2
1

1

$

>>
$*

$*
2 14
%
0;3;<=;<'<
?#!:'!9 @
$%0 1

$
1 $$
%

* *4
90
$1%*

$
%%9,
%@

$% 1

$
(ABB

* * 4 ,
% @#C;<
#+;<.2;#<#
?.!!;;
.2;#<!9 '*
>

$*4

%$ % $

1

$56$
1
1 7
%

$ % $

% % ---------------------------------------------------------------- ."(-/,

,

" 1
(,(
---------------------------------------------------------------- ."
-//,

.'.,9.*

!

$ $ !
+ !

$
.'.
9+
!

!

D

.'.9
1
C

+ +
+$ !
EXHIBIT D Page 33 of 123 EXHIBIT 2
826

!" #

"

"$"

" %"
"$"

!" #

"$"

"

"$" "

!" #

&
"$"

"$" '''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''' ($$"!'$$ $
)$)
$
$ * +

,
,

,

*
+
-
.

/

* "+

* %+
0

1
2
,

3-4

)#
5
+
!
! "

% "
"
%
"
%
%!&
"
3-4

,6)
,22

""&

" %

'''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''' ($! '$$ $)$)
$
$

-

2

. .
)754- 2

!
! "$

74

-
5
(4
4 82

,99
:

5 *,

4

!

$ "$

- 2

!
! "$

45

!
! "
% '''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''''' ($! '$$
$)$)
$
$

-

2

. .
)754- EXHIBIT D Page 34 of 123 EXHIBIT 2
827

!
"
#
$

%&'
#
((
)

#$
(
#* ++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++ ,- *

+#(.*.

/0)0)0&01&&'&0 -0 0 0 2
2&.

!
"
#

(
%&'
#
#

)

#( $

#* ++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++ ,-
*(+*(.*.

)& -0
0 0 2
2&.

!
"

%&'

)

#$
** ++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++ ,- #
+*(.*.

* & -0
0 0 2
2&.

#
* #$

!
"

* #$ %&'

#
* #$ )

# $
++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++ ,- #
+
(.*.

* 2& -0
0 0 2
2&.

#
* #$ EXHIBIT D Page 35 of 123 EXHIBIT 2 828

!"# $%

&
'
%

($ )))))))))))))))))))))))))))))))))))))))))))))))))))))))))))))))) #*+ ('(')((
(%,(
,
(

# -#
! +. . # . / / ,0
! # '$'

!"# $%

&
'
%

($ )))))))))))))))))))))))))))))))))))))))))))))))))))))))))))))))) #*+ (1(')((
(%,(
,
(

&
!#
! +. . # . / / ,0
! # '$'

!"# $%

&
'
%

($ )))))))))))))))))))))))))))))))))))))))))))))))))))))))))))))))) #*+ (%(
)((
(%,(
,
(

.
& #
. +. . # . / / ,0
! # '$'

%%%

!"# %1

&
'(

($ )))))))))))))))))))))))))))))))))))))))))))))))))))))))))))))))) #*+ (%

)((
(%,(
,
(

*"#
! +. . # . / / ,0
! # '$'

EXHIBIT D Page 36 of 123 EXHIBIT 2
829

!
"""""""""""""""""""""""""""""""""""""""""""""""""""""""""""""""" #$%"&''(( )

*

$*

*

* + ,
+ ,'-

-,,

% .
//,0

&&&

&1( !
( """""""""""""""""""""""""""""""""""""""""""""""""""""""""""""""" 2 1"(''(( #3$#3
4
.
.5367 $*

*
,0

* 4
*& 89(& 6

1&189(&
.%
.:.$);4

,*
*
*

/

*
*

<
/

=>
,

,*
*
*
*
*
*

,

/

*
=

*
>
*
/

*
,*

*/

,
*,

,?
/

=>
,

/
@

*,

*A

,
?

B
,
/
,

C
,? ,

C
* C?*/

,
*//
*
*

*,

, =>
,

*
/

*
*
*
<
@
,* @ /"*/
*
*
*A? ,

/*
,

&D ?<*/<<

? ,

**B= >
,

*
*
* ..63.6
;
@

*,

* A

,
?

B
C
*

<<

C
,? ,

*

/

,
*//
*
*

*,

, *?/
,?

* ,

"""""""""""""""""""""""""""""""""""""""""""""""""""""""""""""""" 2 1"&1''(( #3$#3
4
.
.5367 $*

*
2 6$4
4#3(89 """""""""""""""""""""""""""""""""""""""""""""""""""""""""""""""" 2 "(''(( $
3.)43E#3F!#F
$#
.5364
$*

*
2 6$4
4#3 EXHIBIT D Page 37 of 123 EXHIBIT 2 830

!!"

$!
%%
&&&&&&&&&&&&&&&&&&&'
& ( (& )#*

#

&&&&&&&&&&&&&&&&&&' &+ (& ,
-

#%".*

/
#
.!

# 0*0 %% 1

$!1*
#*"
%
2*

!

0

# 0/
# "
./

%0
# !!
#
%."#

$
.

!
3"
3 0
*0 %% 1

4)5!

."
/
%%
# 6#7
"
.0

"
.!"
#

# !
.%3*

/

$#

%$!!
#
1/

!

!"%
!.
!"%
3%8
"
#%%$!
.
3#* %

# !
. "
.6"
%
%
!
. % 1/ %!
#% #7$!& &95)

)

:) ;#7
"
.0

"
.!"
#

# !
.%3*

#$!)%3*
$!"
#%%$!
.
3$!#* %

# !
. "
.$! ;"
%
%
!$! 1/ %!
#% #7$! "%
!.

!"%
3%8$! "
.
.!"
#%

!
$!

.-/"
. ;&

:)
%%

3"%%

&)55:))%/

. "
/
%%
#$!5
. #"

$$!5
.

!
$!5
. ."#

%$!
#
1/

!

$!)5
.)5 &9
)::),

!
#"

$$!5
6

$!
.##$!###

%$!

0
.!

<"
3!
&9):))=))
)

5

)

)
:))=)
)
) )=;5):)>"3
/

$

%
. #<"

?,>,"% . ."%

?
/

$

%$!

%$!;
.6
.
. ;6
.
.

0%$!5) $! !!"

.
!

% $!

6
3
#$! -
@9
#1$$!

# /
.>8#%".

#70
*3"
3 0*6 /%
.$!?& *
.

33%>
8#.0?!$6

%%.
3
1

$!&

$!
!
$!&>"3
/

$

%
.#<"

? 1*

# *6 /%
.$!>

* # 3?&

%
!$!1*

%%.

#1$ >

#%".

.#6%3"%%

?*%%63
0 !. *%#

#

1
1*

*
0*0 %% 1

1 > ?#
.

33%$4 &)*3
A#

/ %/
1
!A

! .%6"
%.

. #

"#

& &)*#
."#
0
*0

%
!$!

%%.

#
."
& B

B

)
:;))
9C9) EXHIBIT D Page 38 of 123 EXHIBIT 2
831

!
"##$%
&'()
*(
+%

&
, -
. #$/
-,*
+0#
+
)

+

(
+
1
+

. #
+,$ /
-,*!%&--%

& 23 4&
*

"
*& +$
5555555555555555555555555555555555555555555555555555555555555555

!5!!6!6! )2

7(%

2(0%828
%

%&
+9..&
:

##

!
:-
:
! %2;
2<2="
:#&+

*+*.,-
#*$&
:

. : >
$.
?1:#&+

##- +*..&# 4#*.,- :-
:#&+:
# $&
:
4,&44#*?
:#&
1:#&
$ .

+

$:
+&:+.
+3* - $&
:
?1:#&+

$ #.,@,-

##+
:,*A
:#&+

,
+:3#4&##

B
+,-
4$.+

,.C.+#3& #+

4C: C3$,- :--:
+&:$-$ #.*.
##+
:
+& ?1:#&+

##
$:,* *.(#
>#
,@(
+& #,@(# $5$* *.A##3& #+

$##:+.-

D 3>-#,$##>#->

3& #+

::B? 1:#&+

*.

.
*. 222
" #.,@,-

##+
:,* A
:#&+

,
+:3#4&##

B(
4C:,- :-
>#>
,.C.+#3& #+

:
&:
($ ,- :--:
+&:$-$ #.*.
##+
-:
+& (-##34$.+3*-
+ #: :
5555555555555555555555555555555555555555555555555555555555555555

!!5!!!6!6! 22%287

%;

!

5555555555555555555555555555555555555555555555555555555555555555

!!5!!6!6! 22%287

%&
+9..&
:

##
! :-
:

%2;
2<2="
:#&+

*+*.,-
#*$&
:

. : >
$.
?1:#&+

##- +*..&# 4#*.,- :-
:#&+:
# EXHIBIT D Page 39 of 123 EXHIBIT 2
832

" #$$%&$%'(#

')'*+,,-
++.+/0+.0-+- 12&%2*)232*$4&%5 3

*26)'17)8*'3""""""""""""""""""""9.+:"/;:<":/ ')'*%38*82&""""""""""""""""""""""9<."+,:<"+ #$$%&$%'1(=

??6
!

:+ /+"

(

" =

/+"

(

')'*+,,-
++,.-0+.0-+-: 12&%2*)232*$4&%5 3

1@*
8

"""""""""""""""""""9 /"/;-;", %
""""""""""""""""""9/ ".;-;"/. 1*$7'$#=$3A(8

" #$$%&$%'(#

" EXHIBIT D Page 40 of 123 EXHIBIT 2
833

!"####################$%&#'()*'
#& ""
######################$&
#()*'
#&

'

+

,
-""

!"####################$#('()*(#'% "" . /0

1234#############$ #
()*(#'% .
/
1135234#########$'#'()*(#'%

30
673880

9
3 "
11###################$
#
%()*

#
95

9
##################$
# %()*

#
!:;<"
9106

=6=82533
1=>0
9
3
3
8
39
?

>38
3 @A9106

1135 6=83801
B1=825
95

910693
31 >0
9
3 3B320BB1=@

910
3 3A910
3 3> 8

3
6

3>93
609368

6C= 5
>0
9
3 @A9106

>
1823425

116

92=.

9106

2

69C1B011

/
625
B>3863

238D38361C0
16 B3D93 D3C>325
95593
6093>35>
18=8

116

93
60 @A9106

11
3 3>92= =8E1

?31
234E

60
1234E1
>>= =8.11C0
16 5?

>1331396835
&F C3?5132>1331?15?

C0
16 99/@ A9106

=8

8
=8# <
1823425

116

92= .

9106

2

69C1B011

/E3
B3D925
95

?31?
238D38361C0
16 93
09
3 E>3 25
95593
6093>35>
18=8

116

593
60 E511CB>386C=5

6 19
9
# %

'

+

,
-""

3880

9
3 =8 "
11###################$'#
%()*

#
95

9
##################$
#&()*

#
!:;<"
9106

=6=82533
1=>0
9
3
3
8
39
?

>38
3 @A9106

1135 6=83801
B1=825
95

910693
31 >0
9
3 3B320BB1=@

910
3 3A910
3 3> 8

3
6

3>93
609368

6C= EXHIBIT D Page 41 of 123 EXHIBIT 2
834

" #$$%&$%'(#

')'*+,-
++-+,.+-./+/ 01&21%'$*$3&%4 5# ')'*%56*61&""""""""""""""""""""""78,"++ -"+

')'*+,-
++9-/.+-./+/9 01&21%'$*$3&%4 5# 0
:*

6 """""""""""""""""""7 9"-8/" %

""""""""""""""""""7,-"-,/";8 0*$<'$#=$5>(6

" #$$%&$%'(#

')'*+,8?
++--/.+-./+/? 2156<$01
2'5*'@
0%1&60)1301&@%3$)32&'*$3&%6'0 5# ')'*%56*61&""""""""""""""""""""""7?8" +9+"+; *1A)'0<)6*'5B--+C D
'

')'*+,8?
++?-/.+-./+/? EXHIBIT D Page 42 of 123 EXHIBIT 2
835

! "# $% $% &'

(
! #$ &) $% $'

*+,

-
-
.(
/

0 /1 2

- ( -

3
.(
(

-
/

3.
33 1

/ - /
-

-- 4
( /

1 2

- / .5 .( -
.
6

- . -
4 3
7 - .( 3/- . 8 - 4
- 38
84 / .(
( (
-

/ ( /
-
-
1 2

- /
.

0 .5 -
.5 /9/

6 4
- (0 /
- ( )#: 40 ( . / 0 (0 4 -

71 2

-

, .5 .( -
.
6

- . -
4 3
7 38
.(
( 00 . 8 - 4
-

/ .(
( (
-

/ ( /
- (
-
( 4 3/- 4
( -

9999999999999999999999999999999999999999999999999999999999999999

'$"#9&&' &';&';$&$#

6'7 1
4 3
! )& '< $" )' 6$7
=
3 3
63
.

0(
4
5(
(
6#& - 4.7 0(- >
-
- -4
=
37 ! #? ?& $$ $< 6?7 @
- ! "& )< $' )< 6"7 .- ! #' %) '% )A B C, . C:

+

-3-

4

D

(50

- -
/
(50
(

9999999999999999999999999999999999999999999999999999999999999999
D&&&%9&&' &';&';$&$#
D

B
! %" &# ?% "?#EE4

,
D

,
3

4
%F /
(

0
3

- / 3
.( ( #
/ 0
- <F / < ( #
/ 0
4
B
C, . C:

-3-

4

D:

(50

-
/
(50 -
(

9999999999999999999999999999999999999999999999999999999999999999 @&&&?9&&' &<;?&;$&$# EXHIBIT D Page 43 of 123 EXHIBIT 2 836

#$%
&' ()
!
*#+ ,,-,./. ,/0../. .,.-/./. 0,/1./. /,../. ,/--2./. 1/220./. 2/11./. 23//0-./. #$% &' ()
!
*!

56)
!

3 #+ !

,2/-./. 7 0.1-./ '585! $ 7
0,2./ !

,,2./. 7 02../ '585! $ 7
0/1./ . !

,0.0./. 94'7 5/--2./. 7 0//./ '585! $ 7
002../ 0 !

,../. #$% &' ()
!
* 7
4 : !"3#+
;
!"4
: 5

/,0./ 7
0..2./ '58! 7
0/,,./
;
!"4
: 5

/2./ 7
0../ '58! 7
0/0./ .
;
!"4
: 5

0-0./ 7
02-./ '58! 7
0/./ 0
;
!"4
: 5

01.1./ / 5

001../ , 5

0/./ #$%
&' ()
!
*

7
5 $!3#+ !

,22./. 7 0.1./ '58! 7
0/-/./ !

,10./. 7 0.0/./ '58! 7
0/1../ EXHIBIT D Page 44 of 123 EXHIBIT 2 837

!
"#$
%&'

( )

* #
+# ,! !
"- .!/
.0.
.0!1. ."

,! 2
3 2 3 45 45"
3
,!

3 23 / 4
"+#

&

6 #&

#
6

0# $# #

7#,7#
("&
8#
(#

+ 91: 4
!
;!..1/1!
14.
"&

(# #<8
#&(
)$8

(#
$# -=

>
?
(# 0

#?
=#$

8#?

0 #?

"*8

6
$
=

>
?
(# 0,
@
&(#

=;

( (#
$# 6#
( #&

(# 0#

(
=#$
6

#&

(# )<

8-=#$

8#?

0#?

&(#

*

' "!
&8
('
*'
8

=
6
6 8#
=#'6

(#
6 8#

#

#?
@
=#
(
#
<*8((
6 '
8

(

((#

# '
8

'#
(
#
(
#
<*8((
6 '
8

0(#

*
(#
&&=

'#
(

((
8'

(0(#

*
(#
&&= 5#A
0 #&
6 =

=

>
?
(# 0&(#
@
=;#

#?
=;#
*

8
>
?
(# = :(&

&
)$8

&
8&-=#$

8#?

0&(#

*
=
,
(

$
$
&&
*'
8

=.
6##'
(0
#
*
=

#?
=+8

>
?
(# )&(#

*

&
8# - "!
&8
(&

(

@6#>&

#
=8
*#6##'= #'6

(#
6 8#

#

&(#

*@ =#

(
6 (8&

()$
(# -=5#A

@# &
8
(=,(&

?
(
*#

=

((
0*

8

).0'
8

# #(8
$

-= ##?
*

*

*'
8

*
8
#&

(# =

?,(
*
%&'

(0*8

0;50+
(
#
#
'
=

?,(
&
&

@# $

=;'

= ;#

=;6
(#

)'#6

-=:
8

<

8 #
&

'
8

)

&8
(0B
6 ,

'
-=:
/# '

:,3
#&
&
?
#
'
=# (
6

8
*

(
=#$
6

&&# (=#
#&

(# 0

&8
(=66
,(

&
0 <,#

*)&

,$8

0 EXHIBIT D Page 45 of 123 EXHIBIT 2
838

!

"
#

$

%

&
"

%

"
%
'( "

"

&

)
)
*
#

+,$-./

(

/

/
(

&
%

/
(
&

/

0

&)1222&"#322

0

(

&

4%
/

#
5
5

/
(&6&7

7

0%

( *

&

*

4

08

"

&#

(
-
9

"
8227
%

+,$8.:

/

74%
7
(
%

:

7

5

(
/

&
%
/

/

&

(&

0%

0

"#822& ! 122

;2

0

!(

<

%

& 7

3';

<
<

,

&
%

%
&
%
&

5
(

(

+,$3.7

7
%

:

=-/
(

(
#
5

0

&12

>

+

!

(

(

?

<

9

(*

=
*

(

&

(&

"

"

"

&#

(

-
"
%
(
+,$@.7

7

7#

7
%
/

#

5
/

0%>

>
%

12 +

+
5

!(

?

*
#

EXHIBIT D Page 46 of 123 EXHIBIT 2
839

! "#$%&'()

*

+
,-.

0

1234%4 *

'55'6)'67'

'3/)6
"#$%8(

,4!4

899

7
*
899

7
*

899

!

899

"#$%1(

84!4

,4!4

-2

899

7
*

899

!

-2

"#$%.(

84 !4
-2

!

-2

"#$%-(+
* '
*

82

*

0

*
*
82

%:5)7:
) "#$%8(7
*

899

,4!4
!

899

*

899

"#$%1(7
*

-2

899

,4 !4
!

-2

*

-2

899

;
0;81!

"#$%.(7
*

-2

!

-2

*
<

-2

"#$%-('

89

3 !
!

< "#$%2(7*

"#$%=(7*
;

))5))
# EXHIBIT D Page 47 of 123 EXHIBIT 2
840

#$

&'

(

)#$

# *
!
+
)

$.

&//012//0/34 2&%

)"5

6%
!
*

7 %

)

8&%

!%
'
9%

(

6

*
* #

%
!6
*

$.*

7!%

8

2020 ;&;/ 300<;60/&02&) 2/02/2&&2 ,60/&)&//012/ /0/=&*

> 202212602) 212?02) /&2 &2)+0/)4;/) 6202)62;2)60 0)6/&00@)2/.0/;&)2/ +2/ ; )2/A2<;/)2/62&0)2/&2 122)2/&2 B) &2/;12)&16/0 202"/&0.013 &,0062;/;/ /&;0201;&.0&300/2022/202"2 /&0.013 212?02 /&@ 2

2 "0

+0/ /&@ 2

2 "0

6202 /&@ 2

2 "0

62;2 /&@ 2

2 "0

EXHIBIT D Page 48 of 123 EXHIBIT 2
841

!"###$ ##%#%&#&#' (
)
*
))
+**!"!

-*"**!"!. ,*

"
"**!"!
/

+/
0
11111111111111123#13$4155 +/*
)*6
.,07 7

1111111111111255135$4155 +$/8

.*9: )
.*9:. *
)
.;9

111111111111111111125'15$$4155 +'/8 ).*9:. (
.
0.<
11251$$4155

+/
0
1111111111111112313$4155 +/*
)*6
.,07 7

111111111111125=135$4155 +$/8

.*9: )
.*9:. *
)
.;9

111111111111111111125315$$4155 +'/8 ).*9:. (
.
0.<
1125$1$$4155

* ""

*
>8
>

>?"!>
"> *>

>

>
8">
(
" >
@
A
">

>

>

B>

>
"

>
>
>
*
8
"

*
,
"!"!
"

"8;

*

*8
;

*
*

(

EXHIBIT D Page 49 of 123 EXHIBIT 2
842

!"
#

$
%& '(

%)* '(

% '(

#

+&

"

!

$
*
"

"

(

)

)-)

"

#

(

,%

"

"
#
%

(

.

$

))

"
#

$
% '(

//////////////////////////////////////////////////////////////// )0001/0203410405 &)*)6 EXHIBIT D Page 50 of 123 EXHIBIT 2 843

! "
#
$ $%%%%%%%%%%%%%%%%%%%%%&''%(')(%'* )%%%%%%%%%%%%%%%%%%%%%&'+%(')(%'* " #
) $%%%%%%%%%%%%%%%%%%%%%&')%)')(%'* )%%%%%%%%%%%%%%%%%%%%%&',%)')(%'* " #
- %%%%%%%%%%%%%%%&,+%*,)(%'* %%%%%%%%%%%%%%%&,.%*,)(%'* " #

/
/

"
#
$
01
2"0
334
2
0 5
034
06
033
2

2
*'7
% "
#
)
01
*'7
33
2
418

4*'7
391
1:0;<"$"-%2433

233;
1300912
044
253

418

*'7
3=
0 12156>152653 467<0
2 1
0 ?12
6336;;= 0
0152:

6
5 306
>36
0
12-$7
*'7
% "
#
-
01# 3 <

33;;= 0 16
12#
0-$7
%

/
/

$?6>#6

6/"
6?/6?
6
6

?
6 >/
6
/

6 @
A#/6
?
6
6

#B6

6 /
#
6 #6

6 #>

#/
)=?

# 7?//"

/>
$)

>

# $2
)
0
C

# $91
)

# $
)
0

# $9
2
1
)
0

# $2

3 )
0

# $91
)
EXHIBIT D Page 51 of 123 EXHIBIT 2
844

!"#$

!"#

&

'!(# !"#
!
!!)*!

$# #!"+

' !"#

!"#$

.

''*"#!
#
!
!'!(#*!

!)

!"+

''*"#
'!
!

&
!
!

''*"#!
#
!

, %,

''*"#!
#$
!

''*"#&
*!

$#!!/
+ !"

'
#!
#
*!

$# #!"+ EXHIBIT D Page 52 of 123 EXHIBIT 2 845

!
!
" #$
%
$%
$%

% &

'
(
)(* &
++(,,,,,,,,,,,,,,,-.", /0,"
1$

2(+

%3+31,,,,,,,,,,,,,,-"",","
-0,

(
14(342(11()

'1(+
(
4

*51
%
(
$4(+(1(3

51 5

1

$
)
&6$&(
)

1 7%
(
$&(
)

'

8(1
(
$%
1

1

$%

+4(1
1

$ %3
5 11&
1
(
$91

($,%,

6
6()$,%,51
&+
1 7
%17$:

;'&6 -.,

(
14(342(11()

'1(+
(
7#2

'3'

3
(
7$&11(

6$ 51(8
3%+4((1
(
7$ (

( ('

+
-,

(
14(342(11()

'1(+
(
(<3
$(3'3$,%,(83
%
(

)((+*

!
!
" %&
%

'
(
)(* &
++(,,,,,,,,,,,,,,,-.", /0,"
1$

2(+

%3+31,,,,,,,,,,,,,,-"",/","
-0,

(
14(342(11()

'1(+
(
4

*51
%
(
$4(+(1(3

51 5

1

$
)
&6$&(
)

1 7%
(
$&(
)

'

8(1
(
$%
1

1

$%

+4(1
1

$ %3
5 11&
1
(
$91

($,%,

6
6()$,%,51
&+
1 7
%17$:

;'&6 -.,

(
14(342(11()

'1(+
(
7#2

'3'

3
(
7$&11(

6$ EXHIBIT D Page 53 of 123 EXHIBIT 2
846

"#
$
%

'#() *(+!,--!!.!/0!/0!. (12** +&'*1 ( 3
*(+4+(51( 31

,. 678 ./ +
("

.! 6!-. /. (1*&2$
8 !!

"#
$
)'
(

1
#

2393
*
#
3
*
#'

*
*

3

:

&
99
#& 2
3 ;
<

239
, !!

"#
$ 2
="

*

32
9

"#
$
%

'#() 29+!!86!!8!60!/0!, 2(12>>/>>2
21=2+'(2+'223(2*+22'1+2= 2'2
2(2+&'*1 2(12>>>>2
2;1(23(1+5*
2=1(22(*+2 1(1=+'1(1291*'+2?+2@&*'2* 2&2= '&+
&1+&'*1 ( 3

29+(1(A291'+0+
=0
12=
29+(1(B 2
/
-6 6.: 8: 2

-8 6.: 8: 291'+(1+;2
+1+34+(5$ <C D D

D
" <

"
#

D
"
<

"
<

D

" <

<

# E

D""

D"<
"

#
<

D
<"
EXHIBIT D Page 54 of 123 EXHIBIT 2 847

!
"

#
$%

&
'
(!)

% **+,*
,
*
--$
%
%()

% ****+,*.,
* %()

% ***+/*,
*

)01%2%-
--$$%
%('$

3 $2
3%
'$%

2$%
4
%4
4
! !* )0
((% 4
5%&(%- 56%

1 6
5
!
'5
7

'4( %

4$

3 $2
3%
*

!
9
% 4

$7**********+,*
:
.*.. .,

!
2 ( 43-;%

0 <)
*********************+/.*=:
*
<)
*********************+/.*,,
*
<)*********************+/.*/

*
<)/*********************+//*:,
*
<).*********************+//*/

*
3%$
6$(
********+/,*/

*
>

<)
05% 44
((
?<
%2 45 ?<2 4
3%$
%@@(5 <)
0%45 ?3-A%
7B

";(%A$2(%
C$&4!
%2 4(&(# <)0!
4
?(

'4
((
'6%A4
5 '34 !?
3

16$7
5 A3
$

(-4?
% $
-
3
2 (?
% $

$
45 ?<
%262565 46%5 ? <2 B
3%$
!2 5 B6%5 ?>4
5 ?>!3 6

2 %@@(5 ?9
2 (' $(24 !%6 4 ;%%55 %
3- 4

A%
7?66
?%@@(5 %
($7( ? 4;(

6%5 '%;%$3%$
)($
' !5
$%
'2 (92$7>2(
'(
%
5

4

?5;
5 '
5;
5 "A%%4%

2;
2 5
(
3
-%
#?2!!
"-%
2 ((;%

A%
7#?
;( 4
?
32$7 4
?)%A4
5 6
5
3%2
<)/0;
%
%6
%
'6&5 ;
7
?2((! ! 52$7

'
$75 ?
% $
$
A $(24

%44 ! 4
6 4 !'2565 " 153%4# <).0<
%2$
A?;%2 45 ?A56

75 ,

EXHIBIT D Page 55 of 123 EXHIBIT 2
848

! "

#######################$%&#'(')#%( " *+#####################$%,#,(')#%( " *+-###################$%,#)'')#%( " *+-###################$%,#,,')#%( " *+-###################$%&#(,')#%( " *+-.###################$%(#%)'%#'( " *'#####################$%,#%,')#%( " *%#####################$%,#',')#%( " */#####################$'0#1/')#%(

+-23+-3
3!2
!.
#
"
4 5
6
*

+
7

########$%,#',')#%( '
2!89:; *
3######################$'0#1/')#%(
"
"
*+#####################$%&#/&')#%( " *'#####################$%,#1&')#%( " *%#####################$%,#%)')#%( " */#####################$%,#',')#%(
:< "
"
*+#####################$%,#,(')#%( " *'#####################$%,#%,')#%(

= 2
7
>
..
78
.
92
?847 ..
!342!8!!@$(#', 8

2
@8 !2!7#88!!
!;
7
> !3
@87.
8"

+- 2!
7# ---------------------------------------------------------

*"
*= 8!
3>A 87A29

78!2
?7
>A -- !98
!.
9A*
!;A
@8-%((
9!; 3!!9!! 8
A!A
9
33!!AB
! !
3!!A 5;3
!3!! "
*+= 8! 32
C!!;
A>
4:> 39!; 9 A
;9
2!A
!>4234 7 4
3
!;4 ! !;A.3 8D3

77
>!
3329A
9

.!!; A
399C4+E' ;3#3
3A
7
>A
3A
7A223E
8
A

2A
- >-98A!!4!
!
332
>A
9 4! .
9A"
A532
345
24 !42;;98
3A58
2!
7 +-+E'FF

@4+((!2#
E
@
A5;3
339! ; A
>899

A
>
.
@+'8A
>
39!;
9
A<!34
3 7
> !; 8!4!;->
!34

4!94
39!; 9! !;9 !;4 3 83!
.
89!
A484 78!4248G>4!899AB4 C;4.2!497
>7
3;
A
G
3
.94!
3
. EXHIBIT D Page 56 of 123 EXHIBIT 2
849

!

#
$
!

%

&&

%

'

'
(

) (
* &

!,-.
/0

'$1
+

#*.23

'
0

$

1

4

+

4

!,-.
/%

52677

.

688%

59677

.

6 !,-.
/4

) %

!,-.
/1

5 6 9

6 !,-.

!,- /+

;

;

&&

*

.77 6

<

%
%

.
.

. EXHIBIT D Page 57 of 123 EXHIBIT 2
850

!

"

#$%&
#' #(

)*
(
$+)%

,
-
#.
#$+)% $+)%/(.00
001. 2 .".
/ 3.+
"#+/ .." +

)+)/ (
.
.
.00.

"4
.00/ -------------------------------------------------------- 56(7!23
7 !2''6
62(6
5'

8'511

9511

, ---------------------------------------------------------- : 7;65:
;!23
7 !2''6
62(6
5'

8'##$
"".
%

9'
-##$".
% ---------------------------------------------------------------- !23 <<=
-<<><=?<8?9<9
2!2*7 2'25'25
2@
65

5(67'
!23
7 $
(%/////////A
>/==9B/C, :#..A8/<<
/ ---------------------------------------------------------------- !23 <9D8-<<
<=?<8?9<9
'25
256'
25'25&2(7

5(67'
!23
7 $( 2

6
5(
!?!257 !
'
7% 7"

//A
=/9D9=/
< (..
6////A
=/CD9=/
< (..
66///A
C/<D9=/
< EXHIBIT D Page 58 of 123 EXHIBIT 2
851

!"
!#$#
!
!%

&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&& '()*+&((,(*$)*$)()-

.
/
0

1
20
+ 34, 56)7 7) 20
) 34, **)7 7) 20
- 34, 4+)7 7) 20
4 344 6*)7 7) 20
, 344 4))7 7)

#
34* 4+)7 7) 0

.
8

20
+.!

92
!
92

::
!
20
)
!
9

;%<
=1
;
>"

"
? 20
-'

9'

#;

#%
!
&;

!92#!#!
#!9 2
<

!<#!98

!
98
#

::
!9/
&

#
1!!

;%9 ##
9 ::
! %
9
1
&#!1

!

/%8

!

9!1
!
!1
!=;

1
!

?9
=
1
;%?9 1

9
%

9
;

!&#!

20
4@1#
#"
!
1
%
9'& !%
%!
9

;&

#

.!#!
=!

? 20
,2
;9
1
!9
;!#
$'%
! &&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&& '()*+&((6(*$)*$)()-

.
/
0

'
=
0
'

&
?
#
2# 3-7 )()7 -( 20
+ 3-* ,()7 -( 20
+& 3-* 7))7 -( 20
+& 3-* ,,)7 -( 20
+&
3-7 (,)7 -( 20
+& 3-+ -7)- )( 20
) 3-* -,)7 -( 20
- 3-* ),)7 -( 20
4 3)6 64)7 -(

#+&1
+&

1

'
=2.

EXHIBIT D Page 59 of 123 EXHIBIT 2
852

!!!!!!!!"
#$!%&

%'!#(

%

)*+ ,-

)
/

0!!!!!!!!!!!!!!!!!!!!!!"
%1!12

%'!#(
.3
4

4
!!!!!!!!!!!!!!!!!!!!!"
#$!&(

%'!#(

4
%!!!!!!!!!!!!!!!!!!!!!"
#$!#&

%'!#( )*

4

4
!!!!!!!!!!!!!!!!!!!!!"
#'!2$

%'!#(

4
%!!!!!!!!!!!!!!!!!!!!!"
#$!1$

%'!#(

4
#!!!!!!!!!!!!!!!!!!!!!"
#$!#'

%'!#(

4
2!!!!!!!!!!!!!!!!!!!!!"
#$!%&

%'!#( 5

)*

6 7
88

8 -
*9
,)
:
7 7

)88+0:
*+

,)++

;
"(!%&
<

)*;

)<<+ )*+
)7

)
!

,
,)++

)<<+/

;

,
)7

)

,

4
<
)

*+!

4
<,)+

)6
=

,) )=
)

*)-

,
+)*

9

6=

)

<+)
-),+
8
-

< <+)/
=

);

#((

- +)

/<
)0
)++
-)++

,
=
+)

=

)-0
0 ++
=
>
+
<+

0 ++=

/0
)
+
0 ++

4

<,)+

<
)0

*?
)++

/<=
)
6:
.)6

)0
- +)

)-<
=

77/-* +=
)
+6
:
*)0
:

< <
)<<
:
0

+)/
:
<+)

< <+)/
=

8 0

,)@)
0

)

6

+
0 7
)0
*)
-
=

-<)

8
)++

/<=

)0
-)7

- ?
:
A%

/0!
)0

0
=

<)

6=

)0
=

)=

**

)0A

,
7=

7 )

<)6

-), =
5)++
:
+7+)0

)0
*
6
=
5
-

)
:
+ <
8
-=
4

=
)0
*)
0:

)+ 7
:
*/
)/
-
,0=
7,
<

*+
< <
A%BB

;
:
((
+*!
<

A;
=
/0

0

)0
- +)

/<=
C)6,)--

<
)

=
C)6 7
8
< <
;

%
,=

C)6
)0
- +)

/<
-<)

=
3

0
:
<

)<<+/ 7
)<,)+
:
+)/6+0:

:
+ -:
)

)0
- +)

/<
-)

)+
)<<+/ 7
-)
)<<+/ 7:

0 << 7

,)0+ 7
8

,
-)

)+=
)77 7:
,
7:

,)+ 7:
*
) 7:

,D)6 7:
+)77 7
,)--
=
>)7
:

<?/
:
8 *
7+):
-)

0 /=

< <
)0

<< 7
8
)-:
+
0 7

; 0=
);-

*
)6

)0
<)0
:
+
0 7

+
7 0
=

*=
<+)/

+
0 7
7 )0
,6 7

,
< <+)/ 7=

)
-),+

< <

,+
0 77
:
)
:
7)
)0

*
-
<
=

)-<

8
)++

)
,

4
<
%=
)-

7
)0

0 7
=

<
)<

<);

6+ 7
:
+
0 7
<+) 7
8

)60

)0A

0 /
)0
7)*
)0

- +)

/<=

)
/
)
8

-
+
<+
,)0

, << 7
)
8
=

)0

,
.
,=

++
=

)0*+)

:
<
:
7 :
@@+
<
)

=
7)++ 7
)0

77 7=
)6
+)
=

+ -*
=

*
*+)

=

E *
)
0:
*
++
8+)

,
+)*

9

6=

E *
)

=
)@)
0

)

6

+)0

-;)+=
*

)0
-+0

-;)+

6

4
)
C/
0 ++
-0+
.>% =
4)
0

;

-0+

)0
- +)

/<
0 ++=

)6
0 ++
=
C)6
+7
0 ++
= EXHIBIT D Page 60 of 123 EXHIBIT 2
853

!
"

#$%&'()*+

,-.//

#
(

.00+

,1.//

#
(

. #$%&'()*

2
+

#$%&'()*

.

, .31

. #$%&'()
*5

.!4

. #$%&'()*

#$%&'3*

6

6
)

!
6

6

6

!
7

#

!

88

(//
.

!
9

'

+

+

)

#
(
()
:
)

(3
#$%&';*6

7

<

<

<

:

9

"

=

"

>

! #$%&'-*<

)

>

!

>

!."

00

* *

. *

>

EXHIBIT D Page 61 of 123 EXHIBIT 2
854

!"#$%&'()$)%&**#+#&#("* )(!,-*

"
.. )(!,/"
..

,

)(!,0)
)(!,1

2)$3#" 2()3%&'()$)%&**#+#&#("* )(!,-* 4

5

4
4
6 )(!,/*
4

6 %&'(7/8-7--79:7-:/7/0 *&"+)&"#*(&";*&"<&$((!"#$* ) + <&*("$";$)
')#3=097>/91> +(("($*!
4

4

=>77

2

4 =/>7

%&'(7/8-7-179:7-:/7/0 *&"+)&"#*(&";*&"<&$((!"#$* ) + ,%&*$)$";$)=1-?0070/ 2

4

=-77

%&'(7/9777079:7-:/7/0 &)$&&*&"&%&)& &)$&'<("$)$@
*&"'$"#(&";*&"&)!A(!"#$* )
+ %&'()$)5)&++#(")(%:%&"$ %(*!)$6 $

;
+,
&&=09/8/907 &'=08/8/907

,
# EXHIBIT D Page 62 of 123 EXHIBIT 2
855

!
"
# $%&' %'&%((())

!
"
#(*+ *,$-,*)&*.&((' %' ////////////////////////////////////////////////////////////////

0
!
!1&"!
&"
&2"
34
3!"

) %("' 5# 6

37
89

6 3

6 3
7

6 39

6 3

"'",
7

3! 2":
""

" 6

37#2*((;6%(*;6%(' <<* 6

3
#
(*;"'=.>?5=% @+()%(+A 6

3#)(;&(&,=(*&'(); '$,.*/='(;' %;(*;6%,%*,*(,*; 6%>')%*>,*;:(*;:)' ,%<<*;0/%&%(),( 5**'(=.;,,;<<* .;"(5/,*& 5"'& ")*!&%0%.:%&" *( ;*5*&*5*?=(%5% *'A;%))?%5=.A; 5(;'%.(;=(*/,*'% 6

3#B5,&,+*5.;%))/ *%.&.*;=/%((()( ,()&2%*,*?$*'(A 6

3
#6%=;
5%(*;"=*,-.* ////////////////////////////////////////////////////////////////

-
7-

0
!
!12"!

3!"

)

!
0(/.

9

////////////////////////////////////////////////////////////////

0
!
!1&"!
2"
34
3!"

) EXHIBIT D Page 63 of 123 EXHIBIT 2
856

!"#$#%!$
&' !(($#%!$

&'
!(%##%!$

&' !(((#%!$

&' !"$(#%!$

&') !"$*#%!$

&# !(!(#%!$

&! !(#(#%!$

&+ #*,+#%!$
-'.
/'//

)

0

1 2

3
0 &
'
4 !(#(#%!$ # .
567

8 &/ #*,+#%!$

&' !"+"#%!$

&# !(,"#%!$

&! !(!%#%!$

&+ !(#(#%!$ 7 9

&' !(($#%!$

&# !(!(#%!$

:
.4;-))45)6.<5
14--
))
/1.
5

= $#(5
.=5

.
4
-

55

84;
/=54
-
)5
'
.
4

&:5

/
;> 5

4>
.
645

.<4;>

6
5
)6>&

8> 0
=5!$$6

8
/

>0
6//

>?

/

> 28/

/

&':5

/.@

8>
;17
;
/6

8
6>--86.
>

;1.
/1 4
1/

8> )/ 5
A
/4
4;
/-
/.
6> 6
)

8>
/6
-6@1'B# 8/
//>
4;>
/>
4> ..
/B5-> -
.> 0
;6
5>

1
-

/
/.;>6
1
)6>
>2
/.
/12.1

-1.8
865/>2-5.
4''B#CC =1'$$
.B=>28//
/6

8>D
;5
66
>D
;-)='#5> D
;
/6

86
>9
/1
/ 4;

8-
5

8;
/11
61

/6

8-6

8-1 /-5
/
-)56

>
---15-1 45

-1.
-15E
;-1

---5
66>?
-1 @81).-

16
4;4/8>
E
/-)
61
/-
) =/>&
=6.
;
/
/1
/-
-/> &6
.>&

8
/--
/5;- 45

8->&
6
5
> &>&5
/--1
1-

/ EXHIBIT D Page 64 of 123 EXHIBIT 2
857

#$

%

!
!
!
&&

%

(

!

)

(

*&

,- . /0

'$1 +
#

#*.23

'
0

1
!

'
4

,- .
/%

52677

.

688%
88

!

!

59677

.

6 ,- . /4

)

%

,- .
/1

5 69

6 ,- . /$

"

.9

6:

!

.9!

6 ,- . /$

,- /+

;

;

;

;

#
!
!!

*

&&!

.77
6<

!

%
%

!

!

+
!!

.

. 0

. ,- 3/;

#
!

=

=
EXHIBIT D Page 65 of 123 EXHIBIT 2
858

!

"
#

%&'()

*
"+

)

"
"
"

$!

$!
,
+
--

--
.

+"
) /)

+

+

, 0)

+
$"

$, 1)+
+

$
!$!

,

+

+
+--+

2+--, ******************************************************** '34 5/0&%5%1/441/ 4&3
%&'6)

3..

%&'7)3..

%&'8)%

%&'()

********************************************************** 9%51:43 9&%:/0&%5%1/441/ 4&3
%&'6)
"

+
"
"

%&'7)*
"

+

**************************************************************** /0&;7<;*;6;;=>7=>7;78 /3 /1/%/1&'3 ? % /0&%5%
1&3 %'1 4&31%/ /0&%5%*/%5//)
1

,,,,,,,,,,,,,,,,,,,,,,,@8<,7;7<,8;
%&'6,,,,,,,,,,,,,,,,,,,,,@8=,A;7<,8;
%&'6*
,,,,,,,,,,,,,,,,,,,@8=,<77<,8;
%&'6*,,,,,,,,,,,,,,,,,,,@8=,AA7<,8;
%&'6*,,,,,,,,,,,,,,,,,,,@8<,;A7<,8;
%&'6*+,,,,,,,,,,,,,,,,,,,@8<,;B7<,8;
%&'7,,,,,,,,,,,,,,,,,,,,,@8=,8A7<,8;
%&'8,,,,,,,,,,,,,,,,,,,,,@8=,7A7<,8;
%&'(,,,,,,,,,,,,,,,,,,,,,@7C,C(7<,8;
6*

6*

+
, /0&%5%

/%D535% E&% 41' '%/F/3D1/5 /0&%5%*/%5//)

6 3"1
,,,,,,,,@8=,7A7<,8;
7 5
9

!
,,,,,,,,,,,,,,,,,,,,,,@7C,C(7<,8; EXHIBIT D Page 66 of 123 EXHIBIT 2 859

! "#$%&%'($%)*+,$--$%(*./$%-%$0#$'1+2/"*%'3'(*+,*+, '2"--$45'3#&4.''/"44%&2&*6& 7&%/$8%"#$6&./& "774*2"#4&(",&%".&
/*''/"44+$."7749.$($%)&%' &+.*.4&5.$%&2&*6&./&(",&%".&'&.-$%./*+ %$87" #&4$( !!

!

!

!

'7/"4.*%$+&%"+5%")&%:
/"*+'"(:"'&%#&"0*+2$++&2.*$+(*./4"#$%&%'1($%): "'.*+74"2&0"+/$4&-$%0'&..&%:%&''8%&7*7&4"9&%: ;"6*'.%&+2/&%$%'*0*4"%.97&"+5"44'0"44 .%&+2/&%':4"'.&%:;*"0$+55%*44&%:<84.*74&8+*.5%*44: =95%"84*25%*44 '7/"4.'7%&"5&%#$>&'"44.97&':"%)$3
"2)&% "+5'*0*4"%.97&."07&%':8,,90$#*4&:
"84)&%3#"+5&%3 7*7&(%"77&%32$+58*.4"9&%374"'.*27*7&4"9&%: &%.*-*&5 /"?"%5$8'("'.&($%)&%*+2485*+,&"5&#".&0&+.: $07"2.$%'$-"44.97&':
$+2%&.&"+50",+&'*.&0*>&%3@ 95"+58+5&%:
$+2%&.&7"+($%):
$+2%&.&'"+5&%:
$+2%&.& '"(:
%*##&%"+5@$%'/$%*+,:

8.,%"+*.&28%#'&..&%: ;%*7")*.0"2/*+&: "44&%34$,4$"5&%"+5#82)&%: $%0 %"*'&%3'4*7-$%0': %&&+28..&%:=&"5&%#$"%53=8#'&..&%3 "4*,+&%3#9"+90&./$5:=*,/7%&''8%&#4$(7*7&@AA$% $6&%34#'7%&''8%&@$6&%:=95%$'&&5&%"+5'*0*4"% .97&:B"2)/"00&%$7&%".$%:B"2)*+,$-7*7&$6&%*+2/&': B"2)'$+"+5'*0*4"%.97&2$07"2.$%:&..4&.&+5&%37$."+5 ($%)&%"7749*+,"'7/"4.34"9)$4532%&$'$.&34*0&32"8'.*2 "+5'*0*4"%.97&0".&%*"4'"7749*+,0&"+'"7749*+,3 5*77*+,$%/"+54*+,$-'82/0".&%*"4':",,*+,3'/&&.*+,3 (/"4*+,3#%"2*+,3.%&+2/C"2)*+,34",,*+,/"00&%:<",+&'*.&3 &7$>9%&'*+3-*#&%,4"''30"'.*2($%)&%(&.$%5%9: $ C$*+.7*7&"+5'.%*77*+,$-'"0&3*+2485*+,%&7"*%$- 6$*5':"6&0&+.#%&")&%"+5'7"5&%3*+2485*+,.$$4,%*+5&%: &%0"28%#:*7&4"9&%*+2485*+,,%"5&2/&2)*+,*+ 2$++&2.*$+(*./7*7&4"9*+,:%&2"'.0"+/$4&'&..&%: %&''8%&7*7&.&'.&%:$'./$4&5*,,&%3"*%3,"'"+5 &4&2.%*2:$(&%#%$$0'(&&7&%:$(&%."07&%'$-"44.97&' &>2&7."''/$(+*+ %$87:"0'&.,8+"+5'.85,8+: *7%"7'.$+&7"6&%"+5%$2)'4*+,&%3*+2485*+,74"2*+,$- '"2)&52$+2%&.&"+5@$%'"+5(&.$%5%9"+5,"#*$+'"+5 '*0*4"%.97&:$."%9'2"%*-*&%$%084.*74&/&"52$+2%&.& 2/*77*+,'2"%*-*&%:$.$"+5;*.2/ *.2/:$.$.*44&%: !"+5#4"'.&%37$.3,8+3+$??4&$7&%".$%':!*,+"44*+,"+5 %*,,*+,: "+)24&"+&%:
%&&24*0#&%:
8%#$#4"'.&%: D*#%"'2%&&53#844-4$".*+2$++&2.*$+(*./4"#$%&%'1($%): D*#%".$%:="?"%5$8'("'.&($%)&%4&"5%&0$6"4:'#&'.$' "+50$45%&0$6"4($%)&% "B$95%*440$5&4

<: "%5+&%;&+6&%0$5&4;= "+5'*0*4"%.97&5%*44': %"2)5%*44&%:B"2)4&,5%*44&%:
",$+5%*44&%:<&2/"+*2"45%*44&%'3"44.97&'%&,"%54&''$- .97&$%0&./$5$-7$(&%:<&2/"+*2"47*7&4"9&%'3"44.97&' %&,"%54&''$-.97&$%0&./$5$-7$(&%:4"'.&%"+57$(5&%: 44($%)$-4$"5*+,374"2*+,"+5#4"'.*+,$-"447$(5&%"+5 &>74$'*6&'$-(/".&6&%.97&%&,"%54&''$-0&./$58'&5-$% EXHIBIT D Page 67 of 123 EXHIBIT 2 860

!"#

$%&'((
) $

#
'**"#
**

)#+#

#
##

#'##+

)
$,

#,

)
$#

$%-'((
) $

#
'

#
. #+")

)
#

+
'0
)

#+$

$% '1-
$

#+

) $

)#+ #

$

)
$#+ #)

)$

!3+

4

,
#+

'2
$

+
#

5$

,

5
-,

#
#

)
)
$) )#+

!3
#

1!0
$6

)

)
6+

#+ 6
+

6

6
# )7

, +
,

+,
#

88, )

$
(( '
9

)
"
"

,
,

;!6

,

7
,
<

<
# <

,

:

9
,

$
+
/

,

+
"

+
)

#

,=

>

)

&!<

#+
,

#
+
>

)

>

)'

**

**

8
#

! 0!

$

' !

> #

$

+

> ' 6!

$

>

)>
) '

EXHIBIT D Page 68 of 123 EXHIBIT 2
861

!"
"#
$$%#
!$ "!&'($)
)
**

"!&+(**

)

"!&,("-)

"!&.()

- /" #0/!"0
!"
"#
$$%#
!$ "!&'($12
13

2
2

4 "!&+($ 12
13

-)

4 !5+655''5675'7+5+, 8!

"
9$

!$
#":$
#
"#!

$ "
%

!"
"3&

4;.5<=+><= /1

(;'55)

!5+>.55'5675'7+5+, %"
$!0$?8?
"#!

$ "
%

!"
"3
14 8

1;,<+>+@@@ !5+>.55+5675'7+5+, %"
$!0$?8?
"#!

$ "
%

!"
"3
"%%##!
"!
7
#
!$"
4
?%
&
;,<+<+6,5

#
&
;,<@<+6,5 &
;,.5<+6,5
"%%##!
"!
&
"$!(

)

)

&
"$!(

)
!5+>.55@5<7+<7+5+, %"
$!0$?8?
"#!

$ "
%
EXHIBIT D Page 69 of 123 EXHIBIT 2
862

!! " !

#
$#%%
! &&'
(&) *(+,
( -+-,(-& )%.%/./%

#
00. ./

123%41#
5#6
768 "9%
7%/9
:%:$1.:
%7/ ,
;$%#2.<1
#%%

/,#

%%
%
/,#
#./
$.$.$
./ %
3

#
7.3$
./*./*%7
$00./=%<
:%#%7
$

%12/&%$$/&00. %#2%/ <$
.:
%#

#
#: 7.
'#
:=#2*:
+.%

/%..:
%..41

%

.
%

8/774

128/ ,
/,
#2
/1.<$%.
>%
$
:$6.
2/977< .#2:
#2./,#
#1<%#%7 $%7:).$.4;.

8

#1/./ 1.$?92. <<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<< (9@
<@@
@!?!?@" +' &:A-& :(&)=()'(,&-' +%7
(9'4,& ,-&,(+
(9' <('(98 ,
#
% $#%%
$"!@ "@ "
@ "@ <" "@ <#"

"@ <"!@ "@ <
"!@
"@ "
"
"@ ""

"@

"@ 7$<<#% %#
%
(9'4()'&' : *-,
(
3
(&) ,('
(9' <('(98 48&1,
#
%"

"@ 48'
%
.
B
; %

"@
(9'4&-'<('(98 "!! "@ "
! "@ "" " "@ "
"@
(9'4B',A-&<('(98 "
@ "@ " "
"@ EXHIBIT D Page 70 of 123 EXHIBIT 2
863

!"#$

%

$$
&

%$()

! ))))))))))))))))))))))))))))))))))))))))))))))))))))))))) *+,,- *..-*. -,/-.0-.* .',/0*$

1 -

1

1 -
))$

10
%
$$

&
1 2

&$4

51+

16%
$
%

1 7&

',/0(*$

&$51+

&$
$
1+%&

1-
%

$$
$$

%

&
$

&
1-

:

1 -
$

&$1-

8
(;" &
!

%

1-

$

1-

1-

1-

;

1-%
%

1 2
)$
)
1

%
1

1'
%
17

&
&

17$
%

$$4()(;"<<

(

!$
%
;

517&

&$1=

$

1=

$$

("1 =

&$
$

1>

$

$$
&
$

4
$$
&

$$
&
$$

16
$
8&

&51
?
$$

$$

%

$

1 0

%

10$

&
4
%

&510

)

1 0
%
$$
10

$
10

$

&$ 48$

'

%$"51,
%

%
%1 ,$
$
$

)

%
$

;

&$1,

%
$

1,

291,

$
%
::

$

1

1

1%

1 @

17
:

51*

',/0()
=
&

96)"*1'

27(A3

1 9

$

16

$

1+

$

1 *

$

8$

4
%

51

$$
1+

',/0()

A! $

%$(

!<<

<<

&

#! $

%$(
EXHIBIT D Page 71 of 123 EXHIBIT 2
864

!"! "

#"
$ !" "%!
&&' ()"&% "%!"% &*"" "" &"+ "" & % % !" &"

,
-%% %.
"%/$"%
)%!"0+& "%% !!!% 1&.%"1 )%." %"" !" % & 1&%% %!%"

%,!

($"&
2!!" ! "!
2
/
0 2
!"
2""
2/ 0
3.
.""
/
0.
4"55.
4 !/&
66 "0
7. %!%%

""! "
"
%.."! !"
$"!.. "

%
8
%""
(

92. 3!"."
:"
:
:

. "
8
7!. "

&!!
/0
#."

*!" .; !
*!/< 0

=:"
%. !

/< 0
! /< 0*%>>! >>5% $!%&%! %<! & < 2%%&!< !" < *!% "%!%>>%!"". !&1"%>> ?+*@7$
@ 27$+:+2$*+
?

?55! EXHIBIT D Page 72 of 123 EXHIBIT 2 865

!"

!##$
!% # &#'

(
)'
*

+,-
+,,
.--/ (
(-

-0 #
-'

(
)'
*-
+,,
.
/

,

-0 !"121&11341&41 ! !5
!#$
#
#6!7
!6!#!6

7#! 8!9 #%! # !#:% 6

-$,
-
-

;;;;;;;;;;;;;;;;;<2;33=;>
'
-(,-,
-)..

<&;11?
/

; !"121&&1341&41 $ #
#! 76!7
!
%
#
-$,
- !"
*
-
%

0;;;;;;;;;<2;33=;>
'
-(,-,
-)..

<&;11?
/

; !"11111341&41 ! !6 7!
%@
-$,
- !"
*%!$$

% 4 !

#
0
-)
7+
$
,
-
;;<3;A3;1 %..)

-
;;;;<3;>A3;1

-
;;;<>;1A3;1 %!$$

%
# B

...))

)-/ )-/
-)
-)

-
-,,
;
# -

+

.
?
B4?

-,-'
-

-)-/ )-/
-; !"11111A4A41 ! !6 7!
%@
-$,
- %

#/.

- &;;;;;;;;;;;;;;;;;;;;;<>;=23;3 ;;;;;;;;;;;;;;;;;;;;;<>;AA3;3 ;;;;;;;;;;;;;;;;;;;;;<>;&3;3 ;;;;;;;;;;;;;;;;;;;;;<;2A3;3 EXHIBIT D Page 73 of 123 EXHIBIT 2 866

!"#

$"$#$

% &'(()*'(&')*''( '++&' %(&')
,-./01-* 23(4*'(35 6%74'()78(8-(&'8('4) #9.&':-,()#',' '*'')#'(&')**&&''(&') *'/4*'&'/&')!(&')!4 *'++&');':*''8'*('4'( 1&&'','(-.) )
++&'' .')
'(1:&'81
8
4&'
8*'';*.!*8
"&'( )&1&'8&1&'0-(*1* &,5)*440,*''1-.5) #1'()#*.'()-(&':&* %<183&'1.)7*4'4: &*.8.&')#'-:'*((('4'( ('48 *&&'0'9&(5 %*-)1*'(&') -&=7.&' ::::::::::::::::::::::::::::::::::::::::::::::::::::::::::::::::
7>6>
:>>
>=
=
>
6 ;
#
? "'4
7
0#

#$
#"
7

:
%5 #'*'
* 6

>

6> 6>

6> : 6

6> : 6
>

6> :, 6
>@

6>
66

6> 6 6

6>

AA

6>
4*:1'(:(*'(1,'
7
0

8 !$#

/

7

:
%5 05
-#'*' 6

6> 0
5 1&'B'9 (
AA

6>
7
0
$
:
%5 6

6>
6A

6> 6 66

6>
6

6>
7
0B
#C$
:
%5 6>

6>
66

6> "

%
1-.'4,,-,&1D'8-'4'4 ,,(813 > *13 1-4'9-. '(3-4,'*: 1- EXHIBIT D Page 74 of 123 EXHIBIT 2 867

!
"
#
$

$
!"
%!
$
#

&#

'

(
)*

$
+,,#(
-

$
.
)#

/'
'

0(
'$
1

"2
-(
. 34$

#(
#
'55(#"
'
3"

3
!
3$

'(
3$
(

&

6
'!
!

$'

5

"
#

#$&(

$

#2
3178 (
9

$

!
$

$

! ""

7
5 '5

$'"

)#$

"'$

#
3&#

$'
0

"
30'"

3 5

3"(
(#

05
'
"!
-1178:: *
31,,"9
'
7*
. 0(

# (
;$##

;$
5&
*
18
$
;$

#(
$#$ <

!
(
53(
3$

3#
3$'$

#(
#
-(
5#

(
53
5

5&'$#
. 55
53

53 !
53"$
53

$=$
5355
5##
/5

3 2(

3&"
53#$!
-!

(. =

5&#
3
$'

5
& *
*
#

3
$'

55

#$'"
(
-
$'

55

$
$
5
$

$
!
(

5.
$#

'

55
335

$$ !
"#!

!
#
&(
-
2$
!

'8. #
5'

'
5'

$
5 3
$'

5$
5& $

$
$

-!

(.

#(
($&
#'

$
$

$
5$&

)$4$

"
335'
3 66

5

5

55
5
$

$#"

'""
>"$

3"'&
$

$
!"
%! >" 06
'!
!
-

#*. "

#

#*!
1;(
#

4/8

)

*
#

)01?+

$

;$
5
45

/
$
$

3(

5

& (
#

&!
/
$
$
(
3(

5

&(
#

&!

!&

53$
5

"
5&!

2*
&!
*
(

5

&#

'

& '$

5

$
5 05$
-
$'

5
5 &#
.

!
$

$
*
@?9,,

("*
'1!5

9::

!
$

::#

(!
!

$#

$
$!!
!5

#
#

!
9

!!

($*
3 5

#

!
3

($*

!
#

$
*
@A9,,

("*
'1!5

9 1$'

5

!

5
$

$
!"
% !
(

$
#$

#(
!

5 1
/

9 EXHIBIT D Page 75 of 123 EXHIBIT 2
868

!"#$%&

'

(

,

(

,#
(

!"#$
%&

!"%* -.

-.$

)

+- .

-.

-.
) +-/

(
(

)+(
- 0

11( -0

) #22 +-3

(

-"

-4 -4

(
$(

-*

(
(

#
#$
-5

$
#

!"6%.

(

-/( -7

-7
- 7
-

-

(

-5

-3
(

-"
)
+-8

(

-4

-

(9

-

):

+
!";%7

$

(

%
-

-

):

+-

):

+

<<

<<

1

% *%

=%

:

: .%

:
:

(

<< $$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$ !>

?3*= ?.3*44
7 .*

>4
!"#%4 >11

!"%>11
(

("
(

!"6%

!";%

EXHIBIT D Page 76 of 123 EXHIBIT 2
869

!"#
$"
%$!$#"#
&
%$%'(

" %
$"
$)
$%*

+
%

%$!$#"#
&
)'

,-"#

$)
$%*

./.0..1
.23.3+.+/

45

6

$)%

"#%

"
7777777777777777777778
/27.1

+2701

"
9 ,%
'

'$):
)
)!

)'"#
%

;-

8+7..
:

' -

$) "$7

$)
#
"
%
87+1

' -

$) "$7
4$"'

8+7..
:

$<
$) "$7

./.0..=
.23.3+.+/

$)%

"#% $%)

)"
777777777777777778
07>/

/.7/+

"
$
%"#
%)$#
%
$&&
87..
:

' -

$) "$7

./+0..+
.23.3+.+/

6

$)%

"#%

)
5 !
(
$#

% "778
/27+?

+27/.

$&&

")

% "
77778
/271?

+27/.

% "
7778
/17.?

+27/.

$< -)
&
)
$&&

")
(

$%'

-%' "%(

"%)
-
) "
$
$
$"

$%
%#"$#7

"%)$$) "
$"

!$
&

):
$
<3:
$"")
%#"%(
$

%(
"$)
%
$"

$%'

-%' "%7

./+0..?
.?3+?3+.+/

6

$)%

"#% -""
$"
'$&)

$,

%

7777777777777777777778
017=>

+272+

+7777777777777777777778
017??

+272+

/7777777777777777777778
0170

+272+

07777777777777777777778
007>?

+272+

17777777777777777777778
0070+

+272+

' )

)
:
$%)777777778
0?70

+272+

5
@

EXHIBIT D Page 77 of 123 EXHIBIT 2
870

"
#
$
#% &'
$
'
(
()

(

$ *+)

,

)
)

)

-

-
$ )

.
,(

$
)
!

/
))/

!
,)

(
!

( $
0
(1.
-
(2

(

%1$$

% *
!*

34
!

)

()
#
!

'$
$,

(

*

,

$
)

$(
)

+

% 5

!

)6'

,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,, 78'9&3,99:6:69& */18*18*/1;
2
$ 78'0 */1*1</*821 78'0,8088% *

)

)=======================>&?=9?=&9 =====================>&:=59?=&9 , ===================>&:=??=&9 ,===================>&:=55?=&9 ,===================>&?=95?=&9 , ===================>&?=9@?=&9 ,$===================>&:=?9?=&9 =====================>&:=&5?=&9 &=====================>&:=5?=&9 3=====================>A=A3?=&9 $ ),!
,
!

= 78'0 8 0/0( -1<*78778/ *80 78'0,8088% %/ *

========>&:=5?=&9 %0
!

B

+

======================>A=A3?=&9 78'0 /<10,8088% =====================>&?=3:?=&9 =====================>&:=A:?=&9 &=====================>&:=&??=&9 3=====================>&:=5?=&9 78'0 B0*C</,8088% =====================>&:=59?=&9 =====================>&:=&5?=&9 21/10 7 !

!
D

(

$
$

(!

#>9=5)

!
#
))

!

$
=1

))+

),
!

= ,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,, EXHIBIT D Page 78 of 123 EXHIBIT 2 871

!
"#
# !
$
%%#
"
&"

'

(
)*
#
%+,,"(
-
"
#
.
)"

/'
'
0(
'#
1

!2
-(
.
34#

"(
"
'55("!
'

3

3#
'(
3#
(

&

6
'

#'
5

!
"
"#&(
#

"5

"2
3178 (
9
'

#

#

#

!!

75'5
#'!

)%
%"#

35

!'#

"
3&"

#'
0

!
30'!

3 5
3!(("

05
'
!
-1%178:: *
31,,!9
'
7*
.0(

" (
;#
""

;#
5&
*
18#
;#

"(
#"#<

(53(%

3#

3"
3#'#
"(
"
-(5"
(53
5
5&'#"
.5553

53 53!#53
#=#
53555""
/5

3
2(
3&!
53"#

-

(.
=

5&"
3#'
5
& *
*
"
!

3#'
55

"#'!
(
-#'
55

#
#
5 #
#
(5.
#%"

'

55
335

##
!"

"
&(
-
2#
'8."
5'
'
5'
*

#
%5
3#'
5#5& #

##

7
-

(.
5!
"(
(#&
"'

##

#5#&

)#4#

!
335'366

55
555

#

#"!

'!!
>!#

3!'&#
# !
$
>!06
'

-

"*.!

"

"*

1%;(
"

4/%8

%)
*
"

)01?+
"(

#

;#

5

45

/
##

3(

5

& (
"

&
/
##
(
3(

5

&(
"

&

&
53#5
!5&

2*
&
*
(

5

&"

'

& '#
5
#505#
-#'
5
5 &"
.

1%!

#

#
*
@?9,,

(!*
'1 5

9::

#

::"
(

#"
##
5
"
"

#
(#*
3 5

"

3

#
(#*

"

#
*
@A9,,

(!*
'1 5

9 1%#'5

5#
# !
$
(
#
"#
"(

5 1%
/
#

#

!

9
"(

&"5
#*

#
*
@ 98A
'!*

5'
&

&"

5'
'#'

#&#( #*

9
5!
#'

EXHIBIT D Page 79 of 123 EXHIBIT 2
872

!"
#

(

)$

)

)

$*
+,&*
-,&*

+,.!

%

(/*

/0
/

/*
/

/

/+1

$

2!&

/*

/*

%

(/ *

/*

/*

%
(/3

$

$
/

%

($

/ 4

55
$ /4 %
66

(/7

$

/

/-
/-

$
$

/&
$ $

/8

2

9!*

$

/3$
/:

/:

/ :

/

$

/8

/7

$

/

%

(/;

$

/,

$< /,
%1

(

=!:

/

/

%1

(/

%1

(,
>>

>>

5

! &!

0!
1

1
*!

1

1

,

>>
$

)

>>
+,?7&0
?*7&--:*&,
+-

!- +55

2!+55
$$
$

EXHIBIT D Page 80 of 123 EXHIBIT 2
873

!

"#
$!
%
&'

(
")'(

(*))+, #

"#)
"&

)- .

&
)!

"#
$!
%)'(

(*
+

"

( &

)- (,
/
0 1
%

$ "

(("
$+
$!

(

+0
0 1

(-2 !
2

"
2
0 #00
2
"

1
2)

$0
0 1
2
))
0
0

)

0
0
")

00 (*)&
,

$ "

(
0
*'
")2
$)
&
+
)

),$)

0$
&
+
*&)

) 45.4 4674 7.4.5
/

)

(
)

$!
"
88888888888888888888895684:.68:

!
3)#+

+

0

'
$
+

(
)
;

"9.8440
+ ""

8!
(

"
)98.: 0
+ ""

8<
+
#!9.8440
"1""

8 45.4 =4674 7.4.5 <>>

)

(
) )

"
888888888888888889 8?55485. !
)#

()
(
)$**"9 8440
+ ""

8 5444.4674 7.4.5 <
,<>,

,><

)

(
)
%

7
- )$
>
'
,
(
)
8895@8.@.6854 **
$

)
888895@8:@.6854
)
8889584@.6854

1
*
**
$$

,$)+ $ )+

),$
)
$

"")
"
)
(
(
8

)

"
&'*

&0170
&

)
(
),&!
),"

)
"$)+ $ )+

)8 544454@[email protected] <
,<>,

,><

)

(
) EXHIBIT D Page 81 of 123 EXHIBIT 2
874

!! " !

#
$#%%
! &&'
(&) *(+,
( -+-,(-& )%.%/./%

#
00. ./

123%41#
5#6
768 "9%
7%/9
:%:$1.:
%7/ ,
;$%#2.<1
#%%

/,#

%%
%
/,#
#./
$.$.$
./ %
3

#
7.3$
./*./*%7
$00./=%<
:%#%7
$

%12/&%$$/&00. %#2%/ <$
.:
%#

#
#: 7.
'#
:=#2*:
+.%

/%..:
%..41

%

.
%

8/774

128/ ,
/,
#2
/1.<$%.
>%
$
:$6.
2/977< .#2:
#2./,#
#1<%#%7 $%7:).$.4;.

8

#1/./ 1.$?92. <<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<< (9"@<@@
@ ?@?@" =(- (:=','): (&-
( (&)
=&',&-'
+%7
(9' =<9%#2"!

<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<<< (9"@<@@ @!?!?@" =(- (:=','): (&-
( :(&)
=&':,&-'
+%7
(9'4,& ,-&,(+
(9' <('(98 ,
#
% $#%%
$"!@ "@ "
@ "@ <" "@ <#"

"@ <"!@ "@ <
"!@
"@ "
"
"@ ""

"@

"@ 7$<<#% %#
%
(9'4()'&' : *-,
(
3
(&) ,('
(9' <('(98 48&1,
#
%"

"@ 48'
%
.
A
; %

"@ EXHIBIT D Page 82 of 123 EXHIBIT 2
875

! "#$%&%'($%)*+,$--$%(*./$%-%$0#$'1+2/"*%'3'(*+,*+, '2"--$45'3#&4.''/"44%&2&*6&7&%/$8%"#$6&./& "774*2"#4&(",&%".& /*''/"44+$."7749.$($%)&%' &+.*.4&5.$%&2&*6&./&(",&%".&'&.-$%./*+ %$87" #&4$( !!

!

!

!"#

$%&'((
) $

#
'**"#
**

)#+#

#
##

#'##+

)
$,

#,

)
$#

$%-'((
) $

#
'

#
. #+")

)
#

+
'0
)

#+$

$% '1-
$

#+

) $

)#+ #

$

)
$#+ #)

)$

!3+

4

,
#+

'2
$

+
#

5$

,

5
-,

#
#

)
)
$) )#+

!3
#

1!0
$6

)

)
6+

#+ 6
+

6

6
# )7

, +
,

+,
#

88, )

$
(( '
9

)
"
"

,
,

;!6

,

7
,
<

<
# <

,

:

9
,

$
+
/

,

+
"

+
)

#

,=

>

)

&!<

#+
,

#
+
>

)

>

)'

**

**

8
#

! 0!

$

' !

> #

$

+

> ' 6!

$

>

)>
) '

EXHIBIT D Page 84 of 123 EXHIBIT 2
877

!"
"#
$$%#
!$ "!&'($)
)
**

"!&+(**

)

"!&,("-)

"!&.()

- /" #0/!"0
!"
"#
$$%#
!$ "!&'($12
13

2
2

4 "!&+($ 12
13

-)

4 !'',55565785'8+5+, #
9 "$%"
$!0$:;
":"&!$:
"#
;$ <!=$
$
$>
!
:
"
%
&

?,@77+6A. /1

(?'55)

!'',555@5785'8+5+, :"&!$:
"#
;$
$
$;
!
:
#!

$ "
%

!"
"3&

4?,@77+6A. /1

(?'55)

&55'B55'5'85'8+5+A :
;#!
"#!$
:!

"
C$

!$:

!$
#
";$
#"D#!

$ "
%
&

(?A,,6+65. &"
::$(
E!
#:

"
$?'+A

) $&"C/!"0(?5A5

) ;$
"
&
?5+A

) F/1

)
-)
)

)

G

)

3-4

)
)H II/!"0( A5?+55)

'55'65?.55)

EXHIBIT D Page 85 of 123 EXHIBIT 2
878

!"#$!%&'( ')(&)* ')'&)$(!+)( '# ',(!) ! "'#-! )&$ &$! '!%&$(! !.&)/!(&) 01,&)(' ,2&)()#,)+(,#,$!',(!) 3*43 %56*3
( !

8 !

8

9 #$!%&'( ')(&$ )&$! '!%&$(! !.&)/!(& )* ')'&)$(!&)('# %)(' ,2',(!) 3*43 )*(*# #.!
8

'#-! )&$ )&$! '!%&)01,&)()#,)+(,#,$! ',(!) 3*43 (! /3 9
9

*((!)" ) .
)%/#)("

!:('$(! #)"

;<;($!"
=46

=46

9

=4 6

)* ')'',(. 3*43 (!
7
9

* !)&><)&$%! &$ )%$! '!%',(!)" 3*43 <#2!
99

9 #$!%'( ')(&$(! !.&)/!(&)* ')'&) $(!&)('# +)(' ,2',(!) EXHIBIT D Page 86 of 123 EXHIBIT 2 879

!
"#$

!
%&%'"(
)!

) *+,#-..
/ %01..
,)2
/ "")
")3 !20
42,

5 6 77 -
.2 ,-+
7-

%01..5,

5 6 77 -
.2,-+
784!

78.5 6 77 -
.2,-+9
,) :-6;<7-
-

5.+71-=;-:. ;>
2,-+77 -
.
!
"#$

!4&%

!")
""
?/

'
@!#!
A"B(
#!)
!
(!
%)("
(&
'"(
)!3

%9"
%?!3
1?C%0#&

+,$

#A%0# 7
C%0#&:- .%0#
72
7
5%0#
8-%0# @
C%0#),
=
6 %0#
7', :%0 :2.-0D+ 7-18-70,
,..5 6 2,-+8-6,8 5,-+.0
0.6 -

9
9E?&@&
)

-! 2

9 ,10 &=

3 "( /

"(

"(
'
!!')"
!
"( 3! 23
0-+
722. 5 -
-;2
7;; 5 2
7:=

F,-,:-2. 5F2#;; 5 2
7:=

"(3
:5-+4.0
-+
7
..
"(3-5 6'-

#6:
!.

EXHIBIT D Page 87 of 123 EXHIBIT 2
880

!
" #$
"% &&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&& '(($$&((# ()*(+*#(+% ,

#
+ -(
)- &&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&& '(-((&((+ ()*(+*#(+! ' +!! .

-#
)( -+
$! ## /., 0, 12

-#
!! -+
$! #%" 03 4
.51 .1.

-#
)( -+
$! --) .6 .16

-#
!! -+
$! #% 7., 89, 01, 1.01: .1

-#
)( -+
$! &&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&& '(-((&((" ()*(+*#(+$

;

-#
+" #-
#) &&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&& '((-!&((+ ()*(+*#(#-

'/ <'01:=, :>, >
. ?

!"
"( !
%! &&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&& '((-!&((" ()*(+*#(#"

987*
. <9
.19*06 ?

))
-" -$
"- &&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&& '(($#&((+ ()*(+*#(#"

@

'/ 4

""
!" #
!" &&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&&& '(+"%&((+ ()*(+*#(#"

EXHIBIT D Page 88 of 123 EXHIBIT 2
881

!"#

$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$ %&'

(
(

# )*+,-./0,1+2'3*4-&,50*+
)

%&'6*2+5*')055*### $$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$ 7%&'

(
(

)*+,-.'*4*32+,8-9&0,4-&,0*+
)

%&'6*0*53*+',:

77
0*53*+',+4-*-);-/< 0

=

>>

.
!

=

>>
=?

=

!

@1

.
A > ="

>
B

.
=

=

> ?
?B

.
>>
@5> A>>

!"

>>

@->

B ="
. > ?

"
.= >>

.=
=

!

>

=

.=

>>

A

@ 3
.

. ="

>>

A>
>>
>

B

@1

>>

=

?
. A

=?.
=

!

. !
.

.>

C
.
"
=
=
.

. ="

>

>>

=>

!"
=

=

!
!

>
"

= >
@%

.

B

@

! A

B

=

@3

>>

@ +

!
!"
=
.

B
="
@4
$>

!>
B

@>! >>

!
>
!

>>
>
=

>>
@)
$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$ %&' :
$

(
(

# %'*324-,54-+54-&,50*+
)

0*)055* 4-,54-+54-&,5E
#
#
# %&'6*.0*)055*. +5*')055* %'*34-&,5E #
#
# $$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$ %&' :##$

(
(

# %'*3.4%F*+.4-,54-+5.)*+,-./0,1+.'3*. '0-+.'*4*3.'-,5**E.+,6*,05-.+,8-9&0,.+,'5*-. +,54%.+,54&G.+5,0+%&+.,35&-%&',*4-&,50*+<
)

&

&

A;" (%

= >)

:
#
EXHIBIT D Page 89 of 123 EXHIBIT 2
882

!

"""""""""""""""#$%"
$&$"$ &&

' ()))*+),

!
,
""""""""""""#'$"$%"
& &$

' -

!
./01

03
"""#%
"
'&
"&&

&
)45)

!

"""""""""""""""""""""""""""#&'"
$
$"%$
678
9:;2<;)2<;1
832<;02
! = 2
8=/<
8
>0
.<8 !<8.
2<;)8 > 1/.= !8.=8
:):;
18;
2;. =2<;

/
= ;22.<8 831/./2
8838

8336 #
"2
;8/
==8 ."
&
%

&
,6

!

"""""""""""""""""""""""""""#''"

"

%

%

& 6

!
883
"""""""""""""""""""""""""""#'&" &
"&
%
&%

& ()))*+) 6

!

"""""""""""""""""""""""""""#& "$'

"

'
%

EXHIBIT D Page 90 of 123 EXHIBIT 2
883

! "# $ %!&''''''''''''''''''''''( )*'+* ,+')+ -! .
''''''''''''''''''( )/'+* ,+')+ 0 1! 2, & 3'''( ))'+* ,+')+ 4444444444444444444444444444444444444444444444444444444444444444
567/455+ 578568,5,)

"
0
2
3''''''''''( 7,'66 65'+5 4444444444444444444444444444444444444444444444444444444444444444
599:45++ 5685+8,5,)

;

0
<

"

-
=

"
0
'''''''''''''''''( 6:'9: ,7'6, 4444444444444444444444444444444444444444444444444444444444444444 >5+56455+ 5*85+8,5,5

+

, ?

>
@0

+ # !
$ (,55555'''''''''''''( ))':, 6)',:
# @!&'''''''''''''( 96'59 69'7/

,''''''''''''''''''''''( ),':5 /9'66

/''''''''''''''''''''''( ))'+9 /6'+7 4444444444444444444444444444444444444444444444444444444444444444 >5+56455/ 5*85+8,5,+

;

-
=

>
@0'''''''''''''''( 66'/6 /:',, 4444444444444444444444444444444444444444444444444444444444444444 >5+56455) 5*85+8,5,+

"

>
@0 2A
$

$& $ $
3'''''''''''( 6+',7 6)'6+ 4444444444444444444444444444444444444444444444444444444444444444 >5+56455* 5*85+8,5,+ EXHIBIT D Page 91 of 123 EXHIBIT 2 884

!" !
"# $$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$ !%! $!%&!"'!%'(!(!

)
*

,-
./001-23

&4&
&& $$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$ !%! $!%5!"'!%'(!(!

7

8
9

:;-<1/,- 0./001-23

&4&
&& $$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$$ !!# $!!%!"'!%'(!(& =./0> 7%

4
(?4
(5
7(

4
&?4
(5
74

4
5?4
(5
7

(%4
(5
7&

&?4
(5
.=-00=;@=./A*=-/.;@0,<:1<:1= =3A =;@.=./A/0=./,0BB1C3A
2 @$B.:.1.;C=./A
=;@1;-2@A -=2=./0=;@=./20 @-A
@:-B=A.DB=A
0=- -D=./,;.:.--3A-20.-$=@ =./@@1@D1:@1<=1: E=@;=-F0

6

7%
=;@=./=0?20
A-=D-./,($ C-=3A@@=./,<:D-./=./=0 @@1@D-./:--@@-23A1.@=;@=./ ,<:D-./=./=0@@1@D-./:-- @@-23A1.@=;@;.:A1/-D0-DG2A =-0'1=./0>1D=-@1A1<B=2A ;.-A*=1@1:=-0>A.11@-1 .0>A7./=@=./A;1-'0'1 >.@1A11/0,.-=0-100 =-103A;0>A11-11;0,D3 7(
=;@=./?20
0=0520
A ;C:1=:%!20
A
=./=0"!!!-
A 8=./=0"!!!-
A-$=D-./ ,4$C-=3A:B0:>20=2@1A.1=./A =BB$0;=./.,1-D$-1003A=BB$0=./ G=;B1A .:=./0HH
HHD;0>A1;B1<.: EXHIBIT D Page 92 of 123 EXHIBIT 2 885

!"#
$
%&'
%
(
)

*+,
%
-
.,,,
%
*
/
.,,,
%
*
0
.1,,
%(

2

3 *

*

2

2

2

2

)

%%

2

(

#

56

7
*
22

2

2

8
6

* )

'"#

*&1
%:1
%
-

#-+,;
&,;
&+;

7 679

5

8 3
* #(

.)

#-+,;
&,;
&+;

4(4
3(

(

<
7 29

0(
.1,,

*

1"#
:1
%
*

3 *#(

*.)

-<3#<

*
2
22

% ================================================================ >>-

2

<)*
+',&:5?+.%.18
+!:1$ 5?+!%!,8%

@

2
2

2

%

2<)*
+',&:
2

2()
3

A

% @
"<)*
5<
8+!.,:<

3* 2
B4

C
#*

62

5

8

2/+&,+.%D2

* <

*

+

2
*2
*!,

1:

2
* % <

*2

C

**

2

8

C

2

8

*
2

*

)

%6
2

7

<

*
"99%
%
*9
9 9
*

%

2

2

2

2

2 EXHIBIT D Page 93 of 123 EXHIBIT 2
886

!!

! "

!

!

#

#
!

!#

#

$
%

!

!

''($''#''$&)*''#+(&+#+(+

,-"
. /0$12
3
222452
526/0$1

#

-"
/"
2
3

"

"

#
#/"
02
3- "#22
-"
#

"

!!"

#2452
526
-"
#

"
!
$

!!

!

"
789

!

!!":&
!

!

$
&
!%

$&)*

#
22;

,<&1/0,. $&)*
=8
22 22
52 526$&)*

!

!=8

( =
-"#22
2
-"
#

"

!!"

#2
52 526
-"
#

!"

"

! &$&)*

#

> #
!
!

!

!!"

(
%

''($''

"

!
!
!

&

!
!

#
"

,-"
.($02
224 ?54526($

!
!
!

0

(
2

-"#224
-"
#

"

!!"

# ?54526
-"
#

"

+($+!

"

EXHIBIT D Page 94 of 123 EXHIBIT 2
887

!

"
#
$
%% !%%
#

&#
&

'(
&&
)

*+
,-)&
. !/,0*+001 0
20*203
!
#&

/,
#

#/

0*
(

)&

(

&
&#

'

$

- )'
001

-)&

&)'

)
$

0
20*203

-)&

#&

&#

4 !4
#
5
##

&

#)

+++++++++++++++++++++++++++++++++++++++++++++++++++++++++++ !6,,$, /"7!$"87!99,!: 9
8,

'

&

)
4$ '
.
(
&(

) '
- '&

) &
&

) )
&#)
&&#

) 8
(
&
)
& &
;
#))
#
(&'

< #

(

;
'
')

)& '#=&
'()& . <#

(

>

)
#:' 00 !

7

0
0 (

) )
#)

;
# &
&'

<#

)

;
'
')

)& <+8##
=&
'()& . <#

)

>

)
#:' 00 !

7

0
0 "# &
'

(

(
##

'(

;

#)

!)

9 1

;
#

'
')

)& '

=&
'()& .

!) >

)
#:' 00 !

7

0
0 $

;
&'
)
'(#&&
)
#

(@ (#)

()
A

)
&

EXHIBIT D Page 95 of 123 EXHIBIT 2
888

!

"

#$%
& '(()

!
%)'('+( ,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,, -*%./0-*- &%-)$.*1
EXHIBIT D Page 96 of 123 EXHIBIT 2
889

Page 1 of 2 ends

City Council and Concurrent AuthoritiesDecember 9, 2025

City Council and Concurrent Authorities
December 9, 2025