Ontario City Council
November 21, 2023

(BB&K 2020)

CITY OF ONTARIO

CHANGE ORDER
Project: Floor Replacement at Various Facilities D&C
21-006
Contract Date: December 21st, 2021
Change Order Number: # 2
Change Order Date:

To: Shaw Integrated & Turf Solutions, Inc.

Atten: Eric Taylor
PO Box 208408
Dallas Texas 75320-88408
THIS CHANGE ORDER FORM SHALL BE USED FOR ALL CHANGE ORDERS ASSOCIATED WITH THE WORK.

NO ADDITIONS OR DELETIONS TO THIS FORM SHALL BE ALLOWED, EXCEPT WITH PERMISSION OF THE CITY OF ONTARIO.

The Contract is changed as follows:
• Increase contract time
• Proposal ID 191963 – CET Division (Emergency) Floor Replacement Contractor agrees to furnish all labor, materials, equipment, and services to perform the Work, modified as described herein, in accordance with the Contract Documents as revised by this Change Order.

NOT VALID UNTIL SIGNED BY OWNER
In consideration of the change(s) described above, the Contract Price is adjusted as follows:

The original Contract Price was $______404,494.08___
Net change by previously authorized Change Orders $______ 22,748.68____ The Contract Price prior to this Change Order was $______427,242.76___ The Contract Price will be changed by this Change Order in the amount of $______75,989.68_____ The new Contract Price including this Change Order will be $______503,232.44____ In consideration of the change(s) describe above, the Contract Time is adjusted as follows:

The Contract Time will be: increased unchanged by ___150_ Days The Contract Time prior to this Change Order was ___570 Days The new Contract Time including this Change Order will be __ 720_ Days 674
46700.00100\33457526.1

(BB&K 2020)
Attachments: Proposal ID: 191963
Contractor accepts the terms and conditions stated herein as full and final settlement of any and all claims arising from this Change Order. The adjustments to the Contract Price and Contract Time in this Change Order constitutes the entire compensation and/or adjustment thereto due to Contractor, including direct, indirect, consequential, and overhead (field and home office) costs, due to Contractor arising out of or related to the change in the Work covered by this Change Order. By signing this Change Order, Contractor agrees to accept the amount of the adjustment to the Contract Price, and the adjustment of the Contract Time, as payment in full for all costs, including direct, indirect, consequential, and overhead (field and home office) costs, related to the change in the Work covered by this Change Order.

Accepted:
(Signature) Eric Taylor, Government Sales Contract
Administrator Date
Approved:
(Signature) Tito Haes, Executive Director Public Works Date Approved:
(Signature) Scott Ochoa, City Manager Date
675
Department: Public Works
Prepared By: Adrian Escamilla
Staff Member Presenting:

Tito Haes, Executive Director Public Works
Reviewed By: Bonnie Tam, Andrea Ampig
Approved By:

Submitted To: Council/OHA
Approved: _______________________________
Continued To: ___________________________
Denied: __________________________________
Item No: 14
SUBJECT: A GOODS AND SERVICES AGREEMENT WITH CONSTANT TECHNOLOGIES, INC.

FOR THE BUILDOUT OF THE ONTARIO POLICE DEPARTMENT REAL TIME

INFORMATION CENTER

CITY OF ONTARIO
Agenda Report
November 21, 2023
SECTION:

CONSENT CALENDAR
RECOMMENDATION: That the City Council take the following actions:

A. Authorize the City Manager or his designee to execute a Goods and Services Agreement with Constant Technologies Inc., of North Kingstown, Rhode Island, for the Ontario Police Department Real Time Information Center (RTIC) in an amount of $721,550; B. Authorize a 10% contingency of $72,155 to address any unforeseen issues that may arise for a total not-to-exceed contract amount of $793,705; and
C. Authorize the City Manager or his designee to execute all documents required for the completion of the project including, but not limited to, contracts, agreements, assessments, easements, reduction of retention accounts, and filing a notice of completion at the conclusion of all construction related activities.

THE FOLLOWING COUNCIL GOALS ARE BEING ACHIEVED:

Focus Resources in Ontario's Commercial and Residential Neighborhoods Invest in the City's Infrastructure (Water, Streets, Sewers, Parks, Storm Drains and Public Facilities)
FISCAL IMPACT: The Fiscal Year 2023-24 Adopted Budget includes appropriations from the Capital Improvement Projects-Measure Q Fund for this project. The total contract amount for the Goods and Services Agreement with Constant Technologies, Inc. for the Ontario Police Department RTIC is $721,550 with a 10% contingency of $72,155 for a total not-to-exceed contract amount of $793,705, funded by Measure Q.

BACKGROUND & ANALYSIS: The buildout of the RTIC at the Ontario Police Department will create a hub for the City of Ontario to bring together data, video, audio and real time information into one centralized place for monitoring. Constant Technologies, Inc. is uniquely qualified to combine turnkey display wall deployment, technology integration, and custom analyst workstations, all 676
specific to Real Time Information Center buildouts. Staff recommends authorizing a Goods and Service Agreement with Constant Technologies, Inc. for the Ontario Police Department RTIC in an amount not-to-exceed $721,550.
677
46700.00100\40935206.1
(BB&K 2023) - 1 - Goods and Services Agreement

CITY OF ONTARIO

GOODS & SERVICES AGREEMENT
This Agreement is made and entered into as of ____________, by and between the City of Ontario, a municipal corporation organized under the laws of the State of California with its principal place of business at 303 East “B” Street, Ontario, California 91764-4196, County of San Bernardino, State of California (“City”) and Constant Technologies Inc. a Corporation with its principal place of business at 125 Steamboat Ave North Kingstown, Rhode Island 02852 (“Vendor”). City and Vendor are sometimes individually referred to as “Party” and collectively as “Parties” in this Agreement.

RECITALS
A. Vendor desires to perform and assume responsibility for the provision of certain services and goods required by the City on the terms and conditions set forth in this Agreement.

Vendor represents that it is experienced in providing similar services and goods to public clients, that it and its employees or subcontractors have all necessary licenses and permits to perform the services in the State of California and that is familiar with and understands the needs of City.

B. City desires to engage Vendor to sell to City the materials and/or equipment and/or render such services as more particularly described in this Agreement.

TERMS

1. SCOPE OF SERVICES.

1.1 General Scope of Services. Vendor promises and agrees to furnish to the City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the Ontario Police Department Real Time Information Center Audio, Video and Furnishing services (“Services”) which are more particularly described in Exhibit “A” attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordance with, this Agreement, the exhibits attached hereto and incorporated herein by reference, and all applicable local, state and federal laws, rules and regulations.

1.2 Goods. Vendor agrees to sell to City and City agrees to purchase the materials and/or equipment (“Goods”) as specified and per the specifications attached hereto and incorporated herein as Exhibit “A.” Unless specifically stated otherwise, the Goods shall be new and unused and of the current production year.
678
46700.00100\40935206.1
(BB&K 2023) - 2 - Goods and Services Agreement

2. TERM.

2.1 The term of this Agreement shall be from October 17,2023 to December 17, 2024, unless earlier terminated as provided herein. Vendor shall provide all Goods and complete the Services within the term of this Agreement and shall meet any other established schedules and deadlines. The Parties may, by mutual, written consent, extend the term of this Agreement if necessary to complete the work.

3. FEES AND PAYMENTS.

3.1 Compensation. Vendor shall receive compensation, including authorized reimbursements, for all Goods provided and Services rendered under this Agreement at the rates set forth in Exhibit “A” attached hereto and incorporated herein by reference. The total compensation shall not exceed Seven Hundred Twenty – One Thousand Five Hundred FortyNine and 49/100 ($721,549.49) without written approval of City’s designee. Extra Work may be authorized, as described below, and if authorized, will be compensated at the rates and manner set forth in this Agreement.

3.2 Payment of Compensation. Vendor shall submit to City a monthly itemized statement which indicates work completed and hours of Services rendered by Vendor and Goods provided. The statement shall describe the amount of Services and Goods provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement. City shall, within 45 days of receiving such statement, review the statement and pay all non-disputed and approved charges thereon.

3.3 Reimbursement for Expenses. Vendor shall not be reimbursed for any expenses unless authorized in writing by City.

3.4 Extra Work. At any time during the term of this Agreement, City may request that Vendor perform Extra Work. As used herein, “Extra Work” means any work which is determined by City to be necessary for the proper completion of the Goods and Services, but which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Vendor shall not perform, nor be compensated for, Extra Work without written authorization from City’s Representative.

4. RESPONSIBILITIES OF VENDOR.

4.1 Control and Payment of Subordinates; Independent Contractor. The Services shall be performed by Vendor or under its supervision. Vendor will determine the means, methods and details of performing the Services subject to the requirements of this Agreement. City retains Vendor on an independent contractor basis and not as an employee. Vendor retains the right to perform similar or different services for others during the term of this Agreement. Any additional personnel performing the Services under this Agreement on behalf of Vendor shall also not be employees of City and shall at all times be under Vendor’s exclusive direction and control. Neither City, or any of its officials, officers, directors, employees or agents shall have control over the conduct of Vendor or any of Vendor’s officers, employees or agents, except as set forth in this Agreement. Vendor shall pay all wages, salaries, and other amounts due such personnel in connection with their performance of providing Goods and Services under this Agreement and as required by law. Vendor shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers’ compensation insurance. 679
46700.00100\40935206.1
(BB&K 2023) - 3 - Goods and Services Agreement

4.2 Schedule of Services.

4.2.1 Vendor shall perform the Services and provide Goods expeditiously, within the term of this Agreement, and in accordance with the Schedule of Goods and Services set forth in Exhibit “B” attached hereto and incorporated herein by reference (“Performance time”). Upon request of City, Vendor shall provide a more detailed schedule of anticipated performance to meet the Schedule of Goods and Services. Vendor agrees that if the Goods are not provided and/or the Services are not completed within the Performance Time, it is understood, acknowledged and agreed that the City will suffer damage.

4.2.2 Neither City nor Vendor shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the nonperforming Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Vendor and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this Section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the Agreement.

4.2.3 Should a Force Majeure Event occur, the non-performing Party shall, within a reasonable time of being prevented from performing, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events and/or delays, regardless of the Party responsible for the delay, shall not entitle Vendor to any additional compensation.

Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement.

4.3 Conformance to Applicable Requirements. All work prepared by Vendor shall be subject to the approval of City.

4.4 Acceptance. The Goods shall be received subject to City’s inspection and right of rejection. The Goods shall not be considered accepted until inspection, testing and/or use of the Goods is found to be in accordance with the City’s specifications. Final inspection of the Goods shall be at the location specified herein, unless otherwise agreed in writing. If the Goods are found at any time to be defective in material or workmanship, or otherwise not in conformance with specifications, City shall have the right, in addition to any other rights which it may have under warranties or otherwise, to reject such Goods in whole or in part. Rejected Goods shall be held at Vendor’s risk for a reasonable time thereafter and shall be returned or disposed of at Vendor’s expense. No rejected Goods shall be replaced by Vendor without written instruction or authorization from City.

4.5 Coordination of Services. Vendor agrees to work closely with City staff in the performance of Services and shall be available to City’s staff, consultants and other staff at all reasonable times.
680
46700.00100\40935206.1
(BB&K 2023) - 4 - Goods and Services Agreement

4.6 Standard of Care; Performance of Employees. Vendor shall perform all Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals in the same discipline in the State of California.

Vendor represents and maintains that it is skilled in the professional calling necessary to perform the Services. Vendor warrants that all employees and subcontractors shall have sufficient skill and experience to perform the Services assigned to them. Vendor represents that it, its employees and subcontractors have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services, including a City business license, and that such licenses and approvals shall be maintained throughout the term of this Agreement. As provided for in the indemnification provisions of this Agreement, Vendor shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Vendor’s failure to comply with the standard of care provided for herein. Any employee of the Vendor or its sub-Vendors who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Services, a threat to the safety of persons or property, or any employee who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed by the Vendor and shall not be re-employed to perform any of the Services provided under this Agreement.

4.7 Warranty. In addition to all warranties which may be provided by law, Vendor warrants that the Goods delivered hereunder shall, (a) be free from defect of material or workmanship and conform strictly to the specifications, drawings, or sample specified or furnished; (b) conform to drawings, plans, specifications, samples or other descriptions furnished, specified, accepted or approved by City; and (c) be merchantable and fit for the purposes intended. The warranty shall be for a period of one (1) year, or such longer period as provided by a manufacturer’s warranty or as agreed to by Vendor and City, from the date of final written acceptance of the Goods by City. This warranty shall survive any inspection, delivery, acceptance, or payment by City of the Goods. Vendor, at its own expense, shall repair or replace, at the option of City, any defective Goods within two (2) business days after receipt of notice from City or within four (4) hours in case of emergency, as determined by City. Vendor also warrants that the Goods are free and clear of all liens and encumbrances whatsoever, that Vendor is conveying good and marketable title to same, and that Vendor owns or has a valid license for all of the proprietary technology and intellectual property incorporated within the Goods. Vendor agrees to indemnify, defend and hold City harmless against any and all third party claims resulting from the breach or inaccuracy of any of the foregoing warranties.

4.8 Reserved.

4.9 Disputes. Should any dispute arise respecting the true value of any work done, of any work omitted, or of any extra work which Vendor may be required to do, or respecting the size of any payment to Vendor during the performance of this Contract, Vendor shall continue to perform the Work while said dispute is decided by the City. If Vendor disputes the City’s decision, Vendor shall have such remedies as may be provided by law.

4.10 Laws and Regulations; Employee/Labor Certifications. Vendor shall keep itself fully informed of and in compliance with all local, state and federal laws, rules and regulations in any manner affecting its performance under this Agreement, including all Cal/OSHA requirements, and shall give all notices required by law. Vendor shall be liable for all violations of such laws and regulations in connection with this Agreement. If the Vendor performs any work knowing it to be contrary to such laws, rules and regulations and without giving written notice to the City, Vendor shall be solely responsible for all costs arising therefrom. City is a public entity 681
46700.00100\40935206.1
(BB&K 2023) - 5 - Goods and Services Agreement
of the State of California subject to certain provisions of the Health & Safety Code, Government Code, Public Contract Code, and Labor Code of the State. It is stipulated and agreed that all provisions of the law applicable to the public contracts of a municipality are a part of this Agreement to the same extent as though set forth herein and will be complied with. These include but are not limited to the payment of prevailing wages, the stipulation that eight (8) hours’ labor shall constitute a legal day’s work and that no worker shall be permitted to work in excess of eight (8) hours during any one calendar day except as permitted by law. Vendor shall defend, indemnify and hold City, its officials, directors, officers, employees and agents free and harmless, pursuant to the indemnification provisions of this Agreement, from any claim or liability arising out of any failure or alleged failure to comply with such laws, rules or regulations.

4.10.1 Employment Eligibility; Vendor. By executing this Agreement, Vendor verifies that it fully complies with all requirements and restrictions of state and federal law respecting the employment of undocumented aliens, including, but not limited to, the Immigration Reform and Control Act of 1986, as may be amended from time to time. Such requirements and restrictions include, but are not limited to, examination and retention of documentation confirming the identity and immigration status of each employee of the Vendor. Vendor also verifies that it has not committed a violation of any such law within the five (5) years immediately preceding the date of execution of this Agreement, and shall not violate any such law at any time during the term of the Agreement. Vendor shall avoid any violation of any such law during the term of this Agreement by participating in an electronic verification of work authorization program operated by the United States Department of Homeland Security, by participating in an equivalent federal work authorization program operated by the United States Department of Homeland Security to verify information of newly hired employees, or by some other legally acceptable method. Vendor shall maintain records of each such verification, and shall make them available to the City or its representatives for inspection and copy at any time during normal business hours. The City shall not be responsible for any costs or expenses related to Vendor’s compliance with the requirements provided for in Section 4.10 or any of its sub-sections.

4.10.2 Employment Eligibility; Subcontractors, and Consultants. To the same extent and under the same conditions as Vendor, Vendor shall require all of its subcontractors, and consultants performing any work relating to this Agreement to make the same verifications and comply with all requirements and restrictions provided for herein.

4.10.3 Employment Eligibility; Failure to Comply. Each person executing this Agreement on behalf of Vendor verifies that they are a duly authorized officer of Vendor, and understands that any of the following shall be grounds for the City to terminate the Agreement for cause: (1) failure of Vendor or its subcontractors, or consultants to meet any of the requirements provided for in Sections 4.10.1 or 4.10.2; (2) any misrepresentation or material omission concerning compliance with such requirements (including in those verifications provided to the Vendor under Section 4.10.2); or (3) failure to immediately remove from this contract any person found not to be in compliance with such requirements.

4.10.4 Labor Certification. By its signature hereunder, Vendor certifies that it is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Workers’ Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services.

4.10.5 Equal Opportunity Employment. Vendor represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or 682
46700.00100\40935206.1
(BB&K 2023) - 6 - Goods and Services Agreement
applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination. Vendor shall also comply with all relevant provisions of City’s Minority Business Enterprise program, Affirmative Action Plan or other related programs or guidelines currently in effect or hereinafter enacted.

4.10.6 Air Quality. Vendor must fully comply with all applicable laws, rules and regulations in furnishing or using equipment and/or providing services, including, but not limited to, emissions limits and permitting requirements imposed by the California Air Resources Board (CARB). Vendor shall specifically be aware of the CARB limits and requirements’ application to “portable equipment”, which definition is considered by CARB to include any item of equipment with a fuel-powered engine. Vendor shall indemnify City against any fines or penalties imposed by CARB or any other governmental or regulatory agency for violations of applicable laws, rules and/or regulations by Vendor, its subcontractors, or others for whom Vendor is responsible under its indemnity obligations provided for in this Agreement.

4.10.7 Water Quality.

4.10.7.1 Management and Compliance. To the extent applicable, Vendor’s Services must account for, and fully comply with, all local, state and federal laws, rules and regulations that may impact water quality compliance, including, without limitation, all applicable provisions of the Federal Water Pollution Control Act (33 U.S.C. §§ 1300); the California Porter-Cologne Water Quality Control Act (Cal Water Code §§ 13000-14950); laws, rules and regulations of the Environmental Protection Agency, the State Water Resources Control Board and the Santa Ana Regional Water Quality Control Board; the City’s ordinances regulating discharges of storm water; and any and all regulations, policies, or permits issued pursuant to any such authority regulating the discharge of pollutants, as that term is used in the Porter-Cologne Water Quality Control Act, to any ground or surface water in the State.

4.10.7.2 Liability for Non-Compliance. Failure to comply with the laws, regulations and policies described in this Section is a violation of law that may subject Vendor or City to penalties, fines, or additional regulatory requirements. Vendor shall defend, indemnify and hold the City, its directors, officials, officers, employees, volunteers and agents free and harmless, pursuant to the indemnification provisions of this Agreement, from and against any and all fines, penalties, claims or other regulatory requirements imposed as a result of Vendor’s noncompliance with the laws, regulations and policies described in this Section, unless such noncompliance is the result of the sole negligence or willful misconduct of the City, its officials, officers, agents, employees or authorized volunteers.

4.10.7.3 Training. In addition to any other standard of care requirements set forth in this Agreement, Vendor warrants that all employees and subcontractors shall have sufficient skill and experience to perform the Services assigned to them without impacting water quality in violation of the laws, regulations and policies described in this Section. Vendor further warrants that it, its employees and subcontractors will receive adequate training, as determined by City, regarding the requirements of the laws, regulations and policies described in this Section as they may relate to the Services provided under this Agreement. Upon request, City will provide Vendor with a list of training programs that meet the requirements of this paragraph. 683
46700.00100\40935206.1
(BB&K 2023) - 7 - Goods and Services Agreement

5. PROJECT MANAGEMENT

5.1 City’s Representative. The City hereby designates Adrian Escamilla, Design and Construction Project Manager, or his or her designee, to act as its representative for the performance of this Agreement (“City’s Representative”). City’s Representative shall have the power to act on behalf of the City for all purposes under this Agreement. Vendor shall not accept direction or orders from any person other than the City’s Representative or his or her designee.

5.2 Vendor’s Representative. Vendor hereby designates Thomas Rivera, Account Manager, or his or her designee, to act as its representative for the performance of this Agreement (“Vendor’s Representative”). Vendor’s Representative shall have full authority to represent and act on behalf of the Vendor for all purposes under this Agreement. The Vendor’s Representative shall supervise and direct the Services, using his best skill and attention, and shall be responsible for all means, methods, techniques, sequences and procedures and for the satisfactory coordination of all work required under this Agreement.

6. INSURANCE.

6.1 Time for Compliance. Vendor shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this Section. In addition, Vendor shall not allow any subcontractor to commence work on any subcontract until it has provided evidence satisfactory to the City that the subcontractor has secured all insurance required under this Section.

6.2 Minimum Requirements. Vendor shall, at its expense, procure and maintain for the duration of the Agreement insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the Agreement by the Vendor, its agents, representatives, employees or subcontractors. Vendor shall also require all of its subcontractors to procure and maintain the same insurance for the duration of the Agreement. Such insurance shall meet at least the following minimum levels of coverage:

6.2.1 Minimum Scope of Insurance. Coverage shall be at least as broad as the latest version of the following: (1) General Liability: Insurance Services Office Commercial General Liability coverage (occurrence form CG 0001); (2) Automobile Liability: Insurance Services Office Business Auto Coverage form number CA 0001, code 1 (any auto); and (3) Workers’ Compensation and Employer’s Liability: Workers’ Compensation insurance as required by the State of California and Employer’s Liability Insurance. The policy shall not contain any exclusion contrary to the Agreement, including but not limited to endorsements or provisions limiting coverage for (1) contractual liability (including but not limited to ISO CG 24 26 or 21 29); or (2) cross liability for claims or suits by one insured against another.

6.2.2 Minimum Limits of Insurance. Vendor shall maintain limits no less than: (1) General Liability: 2,000,000 per occurrence for bodily injury, personal injury and property damage.

If Commercial General Liability Insurance or other form with general aggregate limit is used including, but not limited to, form CG 2503, either the general aggregate limit shall apply separately to this Agreement/location or the general aggregate limit shall be twice the required occurrence limit; (2) Automobile Liability: 2,000,000 per accident for bodily injury and property damage; and (3) Workers’ Compensation and Employer’s Liability: Workers’ Compensation limits as required by the Labor Code of the State of California. Employer’s Liability limits of 1,000,000 per accident for bodily injury or disease. Defense costs shall be paid in addition to the limits. 684
46700.00100\40935206.1
(BB&K 2023) - 8 - Goods and Services Agreement

6.2.3 Manufacturer of Goods. If Vendor is also the manufacturer of any equipment included in the Goods, Vendor shall carry Product Liability and/or Errors and Omissions Insurance which covers said equipment with limits of not less than $1,000,000.

6.2.4 Notices; Cancellation or Reduction of Coverage. At least fifteen (15) days prior to the expiration of any such policy, evidence showing that such insurance coverage has been renewed or extended shall be filed with the City. If such coverage is cancelled or materially reduced, Vendor shall, within ten (10) days after receipt of written notice of such cancellation or reduction of coverage, file with the City evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies. In the event any policy of insurance required under this Agreement does not comply with these specifications or is canceled and not replaced, the City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by the City will be promptly reimbursed by Vendor or the City may withhold amounts sufficient to pay premium from Vendor payments. In the alternative, the City may suspend or terminate this Agreement.

6.2.5 Additional Insured. The City of Ontario, its directors, officials, officers, employees, agents, and volunteers shall be named as additional insureds on Vendor’s and its subcontractors’ policies of commercial general liability and automobile liability insurance using the endorsements and forms specified herein or exact equivalents.

6.3 Insurance Endorsements. The insurance policies shall contain the following provisions, or Vendor shall provide endorsements on forms supplied or approved by the City to add the following provisions to the insurance policies:

6.3.1 General Liability. The general liability policy shall include or be endorsed (amended) to state that: (1) using ISO CG forms 20 10 and 20 37, or endorsements providing the exact same coverage, the City of Ontario, its directors, officials, officers, employees, agents, and volunteers shall be covered as additional insured with respect to the Services or ongoing and complete operations performed by or on behalf of the Vendor, including materials, parts or equipment furnished in connection with such work; and (2) using ISO form 20 01, or endorsements providing the exact same coverage, the insurance coverage shall be primary insurance as respects the City, its directors, officials, officers, employees, agents, and volunteers, or if excess, shall stand in an unbroken chain of coverage excess of the Vendor’s scheduled underlying coverage. Any excess insurance shall contain a provision that such coverage shall also apply on a primary and noncontributory basis for the benefit of the City, before the City’s own primary insurance, deductible, or self-insurance shall be called upon to protect it as a named insured. Any insurance, deductible, or self-insurance maintained by the City, its directors, officials, officers, employees, agents, and volunteers shall be excess of the Vendor’s insurance and shall not be called upon to contribute with it in any way. Notwithstanding the minimum limits set forth in Section 6.2.2, any available insurance proceeds in excess of the specified minimum limits of coverage shall be available to the parties required to be named as additional insureds pursuant to this Section 6.3.1.

6.3.2 Automobile Liability. The automobile liability policy shall include or be endorsed (amended) to state that: (1) the City, its directors, officials, officers, employees, agents, and volunteers shall be covered as additional insureds with respect to the ownership, operation, maintenance, use, loading or unloading of any auto owned, leased, hired or borrowed by the Vendor or for which the Vendor is responsible; and (2) the insurance coverage shall be primary insurance as respects the City, its directors, officials, officers, employees, agents, and volunteers, or if excess, shall stand in an unbroken chain of coverage excess of the Vendor’s scheduled 685
46700.00100\40935206.1
(BB&K 2023) - 9 - Goods and Services Agreement
underlying coverage. Any insurance, deductible, or self-insurance maintained by the City, its directors, officials, officers, employees, agents, and volunteers shall be excess of the Vendor’s insurance and shall not be called upon to contribute with it in any way. Policy shall contain or be endorsed to contain such provisions. Notwithstanding the minimum limits set forth in Section

6.2.2, any available insurance proceeds in excess of the specified minimum limits of coverage shall be available to the parties required to be named as additional insureds pursuant to this Section 6.3.2.

6.3.3 Workers’ Compensation and Employer’s Liability Coverage. The insurer shall agree to waive all rights of subrogation against the City, its directors, officials, officers, employees, agents, and volunteers for losses paid under the terms of the insurance policy which arise from work performed by the Vendor.

6.3.4 All Coverages. Each insurance policy required by this Agreement shall be endorsed to state that: (A) coverage shall not be suspended, voided, reduced or canceled except after thirty (30) days (10 days for nonpayment of premium) prior written notice by certified mail, return receipt requested, has been given to the City; and (B) any failure to comply with reporting or other provisions of the policies, including breaches of warranties, shall not affect coverage provided to the City, its directors, officials, officers, employees, agents, and volunteers. Any failure to comply with reporting or other provisions of the policies including breaches of warranties shall not affect coverage provided to the City, its officials, officers, employees, agents and volunteers, or any other additional insureds.

6.4 Separation of Insureds; No Special Limitations; Waiver of Subrogation. All insurance required by this Section shall contain standard separation of insureds provisions. In addition, such insurance shall not contain any special limitations on the scope of protection afforded to the City, its directors, officials, officers, employees, agents, and volunteers.

Requirement of specific coverage or minimum limits contained in this Section are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance. All policies shall waive any right of subrogation of the insurer against the City, its officials, officers, employees, agents, and volunteers, or any other additional insureds, or shall specifically allow Vendor or others providing insurance evidence in compliance with these specifications to waive their right of recovery prior to a loss. Vendor hereby waives its own right of recovery against City, its officials, officers, employees, agents, and volunteers, or any other additional insureds, and shall require similar written express waivers and insurance clauses from each of its subcontractors.

6.5 Deductibles and Self-Insurance Retentions. Any deductibles or self-insured retentions must be declared to and approved by the City. Vendor shall guarantee that, at the option of the City, either: (1) the insurer shall reduce or eliminate such deductibles or self-insured retentions as respects the City, its directors, officials, officers, employees, agents, and volunteers; or (2) the Vendor shall procure a bond guaranteeing payment of losses and related investigation costs, claims and administrative and defense expenses.

6.6 Subcontractor Insurance Requirements. Vendor shall not allow any subcontractors to commence work on any subcontract relating to the work under the Agreement until they have provided evidence satisfactory to the City that they have secured all insurance required under this Section. If requested by Vendor, the City may approve different scopes or minimum limits of insurance for particular subcontractors. The Vendor and the City shall be named as additional insureds on all subcontractors’ policies of Commercial General Liability using ISO form 20 38, or coverage at least as broad.
686
46700.00100\40935206.1
(BB&K 2023) - 10 - Goods and Services Agreement

6.7 Acceptability of Insurers. Insurance is to be placed with insurers with a current A.M. Best’s rating no less than A:VIII, licensed to do business in California, and satisfactory to the City.

6.8 Verification of Coverage. Vendor shall furnish City with original certificates of insurance and endorsements effecting coverage required by this Agreement on forms satisfactory to the City. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf, and shall be on forms provided by the City if requested. All certificates and endorsements must be received and approved by the City before work commences. The City reserves the right to require complete, certified copies of all required insurance policies, at any time.

6.9 Reporting of Claims. Vendor shall report to the City, in addition to Vendor’s insurer, any and all insurance claims submitted by Vendor in connection with the Services under this Agreement.

7. INDEMNIFICATION.

7.1 Scope of Indemnity. To the fullest extent permitted by law, Vendor shall defend, indemnify and hold the City, its officials, employees, agents and volunteers free and harmless from any and all claims, demands, causes of action, suits, actions, proceedings, costs, expenses, liability, judgments, awards, decrees, settlements, loss, damage or injury of any kind, in law or equity, regardless of whether the allegations are false, fraudulent, or groundless, to property or persons, including wrongful death, (collectively, “Claims”) in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Vendor, its officials, officers, employees, subcontractors, consultants or agents arising out of or in connection with the Services, the Goods or this Agreement, including without limitation the payment of all expert witness fees, attorneys’ fees and other related costs and expenses. Notwithstanding the foregoing, to the extent required by Civil Code section 2782, Vendor’s indemnity obligation shall not apply to such loss or damage which is caused by the sole negligence or willful misconduct of the City.

7.2 Additional Indemnity Obligations. Vendor shall defend, with counsel of City’s choosing and at Vendor’s own cost, expense and risk, any and all Claims covered by this section that may be brought or instituted against City or its officials, employees, agents and volunteers.

In addition, Vendor shall pay and satisfy any judgment, award or decree that may be rendered against City or its officials, employees, agents and volunteers as part of any such claim, suit, action or other proceeding. Vendor shall also reimburse City for the cost of any settlement paid by City or its officials, employees, agents and volunteers as part of any such claim, suit, action or other proceeding. Such reimbursement shall include payment for City’s attorney’s fees and costs, including expert witness fees. Vendor shall reimburse City and its officials, employees, agents and volunteers, for any and all legal expenses and costs incurred by each of them in connection therewith or in enforcing the indemnity herein provided. Vendor’s obligation to indemnify shall survive expiration or termination of this Agreement, and shall not be restricted to insurance proceeds, if any, received by the City, its officials, employees, agents and volunteers.

8. CALIFORNIA LABOR CODE

8.1 Prevailing Wages. Vendor is aware of the requirements of California Labor Code Section 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., (“Prevailing Wage Laws”), which require the payment of prevailing wage rates and 687
46700.00100\40935206.1
(BB&K 2023) - 11 - Goods and Services Agreement
the performance of other requirements on “public works” and “maintenance” projects. Since the Services are being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and since the total compensation is $1,000 or more, Vendor agrees to fully comply with such Prevailing Wage Laws. City shall provide Vendor with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Vendor shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services available to interested parties upon request, and shall post copies at the Vendor’s principal place of business and at the project site. Vendor shall defend, indemnify and hold the City, its elected officials, officers, employees and agents free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws. It is the intent of the parties to effectuate the requirements of sections 1771, 1774, 1775, 1776, 1777.5, 1813, and 1815 of the Labor Code within this Agreement, and Vendor shall therefore comply with such Labor Code sections to the fullest extent required by law.

8.2 Registration. Since the Services are being performed as part of an applicable “public works” or “maintenance” project, then pursuant to Labor Code Sections 1725.5 and 1771.1, the Vendor and all subcontractors must be registered with the Department of Industrial Relations. Vendor shall maintain registration for the duration of this Agreement and require the same of any subcontractor. Notwithstanding the foregoing, the contractor registration requirements mandated by Labor Code Sections 1725.5 and 1771.1 shall not apply to work performed on a public works project that is exempt pursuant to the small project exemption specified in Labor Code Sections 1725.5 and 1771.1.

8.3 Compliance Monitoring. This Agreement may also be subject to compliance monitoring and enforcement by the Department of Industrial Relations. It shall be Vendor’s sole responsibility to comply with all applicable registration and labor compliance requirements. Any stop orders issued by the Department of Industrial Relations against Vendor or any subcontractor that affect Vendor’s performance of Services, including any delay, shall be Vendor’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Vendor caused delay and shall not be compensable by the City. Vendor shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the Department of Industrial Relations against Vendor or any subcontractor.

9. SAFETY.

Vendor shall execute and maintain its work so as to avoid injury or damage to any person or property. In carrying out its services, the Vendor shall at all times be in compliance with all applicable local, state and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of employees appropriate to the nature of the work and the conditions under which the work is to be performed. Safety precautions as applicable shall include, but shall not be limited to: (A) adequate life protection and life saving equipment and procedures; (B) instructions in accident prevention for all employees and subcontractors, such as safe walkways, scaffolds, fall protection ladders, bridges, gang planks, confined space procedures, trenching and shoring, equipment and other safety devices, equipment and wearing apparel as are necessary or lawfully required to prevent accidents or injuries; and (C) adequate facilities for the proper inspection and maintenance of all safety measures.
688
46700.00100\40935206.1
(BB&K 2023) - 12 - Goods and Services Agreement

10. ACCOUNTING RECORDS.

Vendor shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Vendor shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to this Agreement. Vendor shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement.

11. TERMINATION OF AGREEMENT.

11.1 Grounds for Termination. City may, by written notice to Vendor, terminate the whole or any part of this Agreement at any time and without cause by giving written notice to Vendor of such termination, and specifying the effective date thereof, at least seven (7) days before the effective date of such termination. Upon termination, Vendor shall be compensated only for those Services and Goods which have been adequately rendered to City, and Vendor shall be entitled to no further compensation. If terminated for cause because the Vendor refused or failed to deliver the Goods, the City may obtain Goods by whatever method it may deem expedient. If City’s cost of obtaining the Goods, including compensation for additional managerial and administrative services, will exceed the unpaid balance of the Goods, Vendor will be liable for and will pay the difference to City. Vendor may not terminate this Agreement except for cause.

The rights and remedies of the City provided in this Section shall not be exclusive and are in addition to any other rights and remedies provided by law, equity or under this Agreement.

11.2 Effect of Termination. If this Agreement is terminated as provided herein, City may require Vendor to provide all finished or unfinished documents and data and other information of any kind prepared by Vendor in connection with the performance of the Services under this Agreement. Vendor shall be required to provide such document and other information within fifteen (15) days of the request.

11.3 Additional Services. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such manner as it may determine appropriate, goods and services similar to those terminated.

12. GENERAL PROVISIONS.

12.1 Delivery of Notices. All notices permitted or required under this Agreement shall be given to the respective parties at the following address, or at such other address as the respective parties may provide in writing for this purpose:

Vendor:

Constant Technologies Inc. 125 Steamboat Ave North
Kingstown, Rhode Island 02852 – Thomas Rivera – Account Manager
City:

City of Ontario
303 East “B” Street
689
46700.00100\40935206.1
(BB&K 2023) - 13 - Goods and Services Agreement
Ontario, CA 91764-4196
Attn: Adrian Escamilla, Design and Construction Project Manager
Such notice shall be deemed made when personally delivered or when mailed, forty-eight (48) hours after deposit in the U.S. Mail, first class postage prepaid and addressed to the party at its applicable address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.

12.2 Subcontracting. Vendor shall not subcontract any portion of the work required by this Agreement, except as expressly stated herein, without prior written approval of City.

Subcontracts, if any, shall contain a provision making them subject to all provisions stipulated in this Agreement.

12.3 Governing Law; Government Code Claim Compliance. This Agreement shall be governed by the laws of the State of California. Venue shall be in San Bernardino County. In addition to any and all contract requirements pertaining to notices of and requests for compensation or payment for extra work, disputed work, claims and/or changed conditions, Vendor must comply with the claim procedures set forth in Government Code sections 900 et seq. prior to filing any lawsuit against the City. Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to extra work, disputed work, claims, and/or changed conditions have been followed by Vendor. If no such Government Code claim is submitted, or if any prerequisite contractual requirements are not otherwise satisfied as specified herein, Vendor shall be barred from bringing and maintaining a valid lawsuit against the City.

12.4 Time of Essence. Time is of the essence for each and every provision of this Agreement.

12.5 City’s Right to Employ Other Vendors. City reserves right to employ other Vendors in connection with the Goods and Services provided under this Agreement.

12.6 Successors and Assigns. This Agreement shall be binding on the successors and assigns of the parties.

12.7 Assignment or Transfer. Vendor shall not assign, hypothecate or transfer, either directly or by operation of law, this Agreement or any interest herein without the prior written consent of the City. Any attempt to do so shall be null and void, and any assignees, hypothecates or transferees shall acquire no right or interest by reason of such attempted assignment, hypothecation or transfer.

12.8 Construction; References; Captions. Since the Parties or their agents have participated fully in the preparation of this Agreement, the language of this Agreement shall be construed simply, according to its fair meaning, and not strictly for or against any Party. Any term referencing time, days or period for performance shall be deemed calendar days and not work days. All references to Vendor include all personnel, employees, agents, and subcontractors of Vendor, except as otherwise specified in this Agreement. All references to City include its elected officials, officers, employees, agents, and volunteers except as otherwise specified in this Agreement. The captions of the various articles and paragraphs are for convenience and ease of reference only, and do not define, limit, augment, or describe the scope, content or intent of this Agreement.
690
46700.00100\40935206.1
(BB&K 2023) - 14 - Goods and Services Agreement

12.9 Amendment; Modification. No supplement, modification or amendment of this Agreement shall be binding unless executed in writing and signed by both Parties.

12.10 Waiver. No waiver of any default shall constitute a waiver of any other default or breach, whether of the same or other covenant or condition. No waiver, benefit, privilege, or service voluntarily given or performed by a Party shall give the other Party any contractual rights by custom, estoppel or otherwise.

12.11 No Third Party Beneficiaries. Except to the extent expressly provided for in Section

12.7, there are no intended third party beneficiaries of any right or obligation assumed by the Parties.

12.12 Invalidity; Severability. If any portion of this Agreement is declared invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect.

12.13 Prohibited Interests. Vendor maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Vendor, to solicit or secure this Agreement. Further, Vendor warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Vendor, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. Vendor further agrees to file, or shall cause its employees or subcontractors to file, a Statement of Economic Interest with the City’s Filing Officer as required under state law in the performance of the Services. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability. For the term of this Agreement, no member, officer or employee of City, during the term of his or her service with City, shall have any direct interest in this Agreement, or obtain any present or anticipated material benefit arising therefrom.

12.14 Cooperation; Further Acts. The Parties shall fully cooperate with one another, and shall take any additional acts or sign any additional documents as may be necessary, appropriate or convenient to attain the purposes of this Agreement.

12.15 Authority to Enter Agreement. Vendor has all requisite power and authority to conduct its business and to execute, deliver, and perform the Agreement. Each Party warrants that the individuals who have signed this Agreement have the legal power, right, and authority to make this Agreement and bind each respective Party.

12.16 Counterparts. This Agreement may be signed in counterparts, each of which shall constitute an original.

12.17 Entire Agreement. This Agreement contains the entire Agreement of the parties with respect to the subject matter hereof, and supersedes all prior negotiations, understandings or agreements. This Agreement may only be modified by a writing signed by both parties.

SIGNATURES ON NEXT PAGE
691
46700.00100
\40935206.1
(BB&K 2023)
- 15- Goods and Services Agreement
692
46700.00100\40935206.1
(BB&K 2023) - 16 - Goods and Services Agreement

SIGNATURE PAGE FOR GOODS & SERVICES AGREEMENT

BETWEEN THE CITY OF ONTARIO
AND CONSTANT TECHNOLOGIES INC.

IN WITNESS WHEREOF, the Parties have entered into this Agreement as of the day and year first above written.

CITY OF ONTARIO Constant Technologies Inc.

By:

Its:

Printed Name:

By:

Its:

Printed Name:
[If Corporation, TWO SIGNATURES,
President OR Vice President AND
Secretary OR Treasurer REQUIRED]
Approved By:

Scott Ochoa
City Manager
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:

Assistant City Clerk
693
EXHIBIT “A”

SCOPE OF SERVICE
694
695
696
697
698
699
700
701
702
703
704
705
706
707
Department: Public Works
Prepared By: Daniel P Beers
Staff Member Presenting:

Tito Haes, Executive Director Public Works
Reviewed By: Bonnie Tam, Andrea Ampig
Approved By:

Submitted To: Council/OHA
Approved: _______________________________
Continued To: ___________________________
Denied: __________________________________
Item No: 15
SUBJECT: AN AMENDMENT TO THE PROFESSIONAL SERVICES AGREEMENT WITH KLEINFELDER, INC. FOR ON-CALL GEOTECHNICAL CONSULTING, MATERIALS

TESTING, AND SPECIAL INSPECTION SERVICES

CITY OF ONTARIO
Agenda Report
November 21, 2023
SECTION:

CONSENT CALENDAR
RECOMMENDATION: That the City Council authorize the City Manager or his designee to execute Amendment No. 4 to the On-Call Professional Services Agreement with Kleinfelder, Inc., of Ontario, California, to provide on-call geotechnical consulting, materials testing, and special inspection services for the City Hall Expansion - Parking Structure Project in the amount of $461,981 for a total contract amount not-to-exceed $511,746.

THE FOLLOWING COUNCIL GOALS ARE BEING ACHIEVED:

Invest in the City's Infrastructure (Water, Streets, Sewers, Parks, Storm Drains and Public Facilities)
FISCAL IMPACT: The Fiscal Year 2023-24 Adopted Budget includes appropriations in the Capital Projects Fund for this project. The proposed Amendment No. 4 for the geotechnical consulting, materials testing, and special inspection services for the City Hall Expansion – Parking Structure Project is $461,981 for a total not-to-exceed contract amount of $511,746.

BACKGROUND & ANALYSIS: The City Hall Expansion includes a new Fire Station 01, Fire Administration Building, New City Hall Services Building, and a Parking Structure. Kleinfelder, Inc. completed the Phase 1 Geotechnical Survey for the City Hall Parking Structure and is familiar with the project scope. Construction of the City Hall Parking Structure will require additional geotechnical surveys along with special inspections. If approved, Staff anticipates the City Hall Parking Structure to be operational by March 2025.
708
46700.00100\33287662.1

BB&K 2020
AMENDMENT NO. 4 TO THE PROFESSIONAL SERVICES AGREEMENT

BETWEEN THE CITY OF ONTARIO AND
KLEINFELDER, INC.

1. Parties and Date.

This Amendment No. 4 to the Agreement (as defined herein) is made and entered as of ____________, by and between the City of Ontario (“City”) and Kleinfelder, Inc, a California Corporation (“Consultant”). City and Consultant are sometimes individually referred to as “Party” and collectively as “Parties.”

2. Recitals.

2.1 Agreement. The City and Consultant have entered into an agreement entitled “On-Call Material Testing & Geotechnical Engineering Services” dated March 7, 2023 (“Agreement”).

2.2 Amendment Purpose. The City and Consultant desire to amend the Agreement to add Special Inspection and additional Geotechnical Services for D&C22-012 City Hall Parking Structure and increase the not to exceed amount by FOUR HUNDRED SIXTY-ONE THOUSAND NINE HUNDRED EIGHTY-ONE DOLLARS ($461,981.00). The Parties have heretofore entered into the Amendment No. 1 dated April 4, 2023, Amendment No. 2 dated May 2, 2023, Amendment No. 3 dated May 17, 2023,

2.3 Amendment Authority. This Amendment No. 5 is authorized pursuant to Section 3.2.4 of the Agreement.

3. Terms.

3.1 Amendment. Section 3.2.1, Exhibit A of the Agreement is hereby amended in its entirety to read as follows:

3.2.1 Compensation. Consultant shall receive compensation, including authorized reimbursements, for all Services rendered under this Agreement at the rates set forth in Exhibit "A" 709
46700.00100\33287662.1

BB&K 2020
and attached hereto and incorporated herein by reference. The total compensation shall not exceed Five Hundred Eleven Thousand Seven Hundred Forty-Six Dollars ($511,746.00) without written approval of the City Council or City Manager, as applicable. Extra Work may be authorized, as described below, and if authorized, will be compensated at the rates and manner set forth in this Agreement.

Exhibit “A” – Scope of Services is hereby amended to add Attachment A which is hereto and incorporated herein by reference. All other previously added or deleted scope of services are retained in their entirety.

3.2 Continuing Effect of Agreement. Except as amended by this Amendment No. 4, all other provisions of the Agreement remain in full force and effect and shall govern the actions of the parties under this Amendment No. 4. From and after the date of this Amendment No. 4, whenever the term “Agreement” appears in the Agreement, it shall mean the Agreement as amended by this Amendment No. 4.

3.3 Adequate Consideration. The Parties hereto irrevocably stipulate and agree that they have each received adequate and independent consideration for the performance of the obligations they have undertaken pursuant to this Amendment No. 4.

3.4 Severability. If any portion of this Amendment No. 4 is declared invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect.

3.5 Integration. This Amendment represents the entirety of the Parties’ understanding relating to the subject of this Amendment, including written or verbal communications between the Parties, which shall have no relevance unless expressly incorporated herein. This is an integrated amendment.
[SIGNATURES ON FOLLOWING PAGE]
710
46700.00100\33287662.1

BB&K 2020
SIGNATURE PAGE FOR AMENDMENT NO. 5 TO PROVIDE MATERIAL TESTING AND

GEOTECHNICAL ENGINEERING SERVICES BETWEEN THE CITY OF ONTARIO AND KLEINFELDER, INC.

IN WITNESS WHEREOF, the Parties have entered into this Amendment No. 5 as of the day and year first above written.

CITY OF ONTARIO KLEINFELDER, INC.

By:

Its:

Printed Name:

By:

Its:

Printed Name:
[If Corporation, TWO SIGNATURES,
President OR Vice President AND Secretary
OR Treasurer REQUIRED]
Approved By:

Scott Ochoa
City Manager
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:

City Clerk
711
46700.00100\33287662.1

BB&K 2020
Exhibit A
Scope of Services
(Please See Attached)
712
MW180685.001P/ONT23P158153 Page 1 of 8 September 11, 2023 Copyright 2023 Kleinfelder www.kleinfelder.com
620 S. Magnolia Bldg. G, Ontario, CA 91762 p | 909-.657.1716 f | 909.988.0185 September 11, 2023
Kleinfelder Proposal No.: MW180685.001P
City of Ontario
Mr. Daniel Beers
1333 S. Bon View Avenue
Ontario, California 91761
SUBJECT: Request for Additional Authorization to Provide Special Inspection and Materials Testing Services
Parking Structure & Storm Drain Installation Project
Intersection at East D Street and North Sultana Avenue
Ontario, California 91764
Dear Mr. Beers:

Kleinfelder Inc. is pleased to present this request for additional authorization to provide special inspection and materials testing services for the subject project. Kleinfelder has recently completed a geotechnical investigation on this site which consisted of document research, performance of onsite borings, laboratory testing, engineering evaluation, and report preparation.

Our knowledge of the existing site conditions provides additional benefits to the City as the project moves into construction. This request for additional authorization includes a description of our understanding of the project, our proposed scope of services, and our estimated fees.

Kleinfelder is committed to providing quality service to its clients, commensurate with their wants, needs, and desired level of risk. If a portion of this request for additional authorization does not meet your needs, or if those needs have changed, Kleinfelder stands ready to consider appropriate modifications, subject to the standards of care to which we adhere as professionals.

Modifications such as changes in scope, methodology, and scheduling may result in changes to the risks assumed by the client, as well as adjustments to our fees.

The purpose of our services is to provide quality assurance inspection and testing to assess compliance with the project plans and specifications during construction. This request for additional authorization is based on our knowledge of the project and recent experience with similar type projects. The following information forms the basis of this request for additional authorization and cost estimate.

PROJECT UNDERSTANDING
Kleinfelder understands that the City of Ontario plans to construct a new 6½ -story above ground parking structure south of the proposed Fire Station No. 1 located southwest of the intersection at East D Street and North Sultana Avenue. We anticipate that the design-build parking structure will be constructed with reinforced concrete and encompass an approximately 48,750 square foot area. Additionally, the property includes an existing 24-inch storm drain line and existing drainage Attachment "A"
713
MW180685.001P/ONT23P158153 Page 2 of 8 September 11, 2023 Copyright 2023 Kleinfelder www.kleinfelder.com
KLEINFELDER 620 S. Magnolia Bldg. G, Ontario, CA 91762 p | 909-.657.1716 f | 909.988.0185 system located on North Sultana Avenue. Given the redevelopment of the property, the City plans to discontinue the existing storm drain line and install a new storm drain connecting to the existing drainage infrastructure on North Sultana Avenue.

During construction, the project will require onsite testing and observation services for soil and asphalt as well as onsite inspection services during placement of rebar, masonry components, concrete, and post-tensioning. We understand onsite welding inspections for the manufactured stairs may also be required. At the time of our request for additional authorization preparation, a construction schedule, project plans, and project specifications were not available for our review.

SCOPE OF SERVICES
Kleinfelder will provide special inspection and materials testing services on an as-requested basis for the parking structure and storm drain installation project. Our services will include onsite observation, inspection, and materials testing during site grading, utility trench backfill, site and trench paving, reinforcing steel and tendon placement, Portland cement concrete placement, structural masonry placement, post-tensioning, bolting, welding, and all associated laboratory testing.

During construction we anticipate assisting the City of Ontario with contractor submittal reviews. We anticipate these reviews will include proposed Portland cement concrete mix designs. Following completion of our special inspection and materials testing services we will prepare final summary reports of our observations, inspections, and materials testing services.

Our services will be coordinated with the City’s onsite representatives. The overall proposed scope of Kleinfelder services are provided in the following tasks which provide the basis of our cost estimate.

SPECIAL INSPECTION & MATERIALS TESTING SERVICES
Site Grading & Utility Trench Backfill
We will provide a field technician working under the supervision of a Geotechnical Engineer to perform observation and compaction testing services during site grading and utility trench backfill activities. This service will also include onsite observation and testing during placement of aggregate base. In general, our services will be provided on a continuous basis during site grading and utility trench backfill operations.

During construction, samples of the engineered fill soils and aggregate base will be collected for laboratory maximum density/optimum moisture content determinations. Additionally, samples of pipe bedding materials will be collected for laboratory sand equivalent value testing. We anticipate samples of aggregate base will be collected for R-value determinations, sand equivalent value, sieve analysis, and Los Angeles abrasion testing to assess conformance with data provided in the geotechnical report and/or contractor submittals.

Structure Access/Trench Paving
Our services will include preparation of the subsurface materials prior to surface paving and monitoring of the surfacing materials upon arrival to the site. Our representative will notify the City Inspector immediately should conditions exceed accepted ranges for the material type placed.

In-place density testing and monitoring of construction materials will be performed continuously during placement activities. Samples of the construction materials will be collected daily for 714
MW180685.001P/ONT23P158153 Page 3 of 8 September 11, 2023 Copyright 2023 Kleinfelder www.kleinfelder.com
KLEINFELDER 620 S. Magnolia Bldg. G, Ontario, CA 91762 p | 909-.657.1716 f | 909.988.0185 laboratory testing. At this time, we anticipate that vehicular access to the parking structure and storm drain trench paving will consist of placement of asphalt concrete on crushed aggregate base. Field sampling and laboratory testing for asphalt paving is expected to include stability value (S-value), laboratory test maximum density (LTMD), binder content, and gradation on composite samples. Should Portland cement concrete be utilized as the surfacing material for vehicular access to the parking structure, we will perform onsite sampling and preparation of field cast specimens for laboratory compressive strength determinations.

Portland Cement Concrete Placement
Kleinfelder will provide ACI certified field technicians and ICC certified special inspectors to observe and test structural concrete. Our inspectors will observe placement, sample, and test structural concrete used in footings, columns, beams, slab-on-grade, and post tensioned decks.

Our field services will include monitoring of slump, mix-design identification, temperature testing, time of batching/placement, mixing time, and casting of concrete cylinders for compression testing of structural concrete delivered to the site. We will pick up and deliver concrete specimens to our laboratory for compressive strength testing.

We have assumed that Portland cement concrete batch plant inspection will not be required. If requested, Kleinfelder can provide batch plant inspection after receiving appropriate authorization from the City. We anticipate that the contractor will provide the proper submittals for concrete that will eliminate the need for qualification testing by us, therefore our fee does not include testing of concrete aggregates for acceptance testing.

Placement of Reinforcing Steel and Tendons
Kleinfelder will provide an ICC certified special inspector to inspect placement of the reinforcing steel and post-tensioned tendons prior to placement of concrete. Reinforcing steel is checked for size, spacing, type, grade, identification, placement, and configuration. Tendons are checked for size, type, identification, spacing, profile, and alignment. Stressing of tendons will be observed on a continuous basis and stresses and elongations will be recorded. We will also collect samples of reinforcing steel and tendons which will be transported to our facility for laboratory testing as required by the project plans and specifications.

Structural Masonry Observation
During the lay-up of masonry units, our ICC certified special inspector will inspect reinforcing steel utilized during masonry construction activities for size, grade, vertical and horizonal placement, and clearances. Additionally, they will observe if cleanouts are provided for the first course of each pour if high lift method is used, mortar ingredients and batching techniques, and they will prepare mortar compression test specimens for laboratory testing.

During grouting observations, our inspector will observe the grout mix for conformance to the approved mix design, slump is in general accordance with specifications, and consolidation during placement and later during reconsolidation. Our inspector will monitor time between batching of grout, flow of grout throughout wall, grout pour height, and they will prepare grout specimens and/or prisms.

Our inspector will collect samples of mortar, grout, and composite masonry prisms following field curing for transportation to our laboratory for further curing and determination of compressive strength.

715
MW180685.001P/ONT23P158153 Page 4 of 8 September 11, 2023 Copyright 2023 Kleinfelder www.kleinfelder.com
KLEINFELDER 620 S. Magnolia Bldg. G, Ontario, CA 91762 p | 909-.657.1716 f | 909.988.0185 Field Welding and Bolting Inspection
During field welding observations, our ICC certified special inspector will check all welders’ certifications and the Welding Procedure System (WPS). We will inspect joints for proper preparation, including bevel, root faces, and root opening. Continuous inspection will be performed on complete and partial joint penetration groove welds, multiple pass fillet welds, slot welds, and single pass fillet welds as required by the contract documents.

At this time, we anticipate that structural steel components will be fabricated in a City of Los Angeles approved fabrication shop and will reduce onsite welding inspections and eliminate the need for fabrication shop inspection services by Kleinfelder.

During high strength bolting observation, we will review type of joint specified, check bolts, nuts, and washers for compliance to project specifications, review the procedure for installation of bolts, monitor the installation of bolts to verify the selected installation procedure is properly used to tighten and torque the bolts per the project requirements.

LABORATORY TESTING SERVICES
Our laboratory testing will be conducted in general accordance with ASTM procedures. Samples collected from the job site will be secured and delivered to our local Ontario laboratory for testing as required. Our budget for materials testing includes laboratory maximum density/optimum moisture content; sieve analysis; sand equivalent value; Los Angeles abrasion; asphalt stability value; asphalt binder content and gradation; laboratory test maximum density; R-value determinations; compressive strength testing of concrete, masonry block, masonry mortar, masonry prisms, and masonry grout; tension, elongation, and bend testing of reinforcing steel; and tension and elongation for PT strands to check conformance with the project specifications.

Laboratory testing will be performed in accordance with the plans, specifications, and local jurisdictional requirements to evaluate whether the materials comply with project requirements and are suitable for their intended use. Results of laboratory testing will be reviewed and prepared in typewritten reports for submittal to the appropriate City staff, project manager, and designated team members. Results of tests indicating material not meeting minimum project requirements will be immediately communicated with the project design professionals.

PROJECT MANAGEMENT & ADMINISTRATION
Kleinfelder’s Project Manager, Mr. Mike Dorsch, will coordinate our services with the City and other stakeholders. Mr. Dorsch will be supported with in-house special inspectors and technicians from our local Ontario office and laboratory having the appropriate experience and certifications necessary to perform observations, inspections, and materials testing services on the project site.

Construction Meetings
Our proposed scope of services and fee estimate includes attendance at a pre-construction conference. During this meeting we will identify the project team members, their project roles for development of a distribution list of our reports, review the construction schedule, and discuss potential construction concerns. We have also included attendance during additional construction meetings to be held during construction activities.
716
MW180685.001P/ONT23P158153 Page 5 of 8 September 11, 2023 Copyright 2023 Kleinfelder www.kleinfelder.com
KLEINFELDER 620 S. Magnolia Bldg. G, Ontario, CA 91762 p | 909-.657.1716 f | 909.988.0185 Technical Management
Kleinfelder will provide technical consultation. These services may include field observations, research, as requested engineering review, interpretation of laboratory results, communication, and generation of requested professional recommendations.

DFRs summarizing the work performed and conformance of the work with the project requirements will be reviewed by our project manager. Items found in non-compliance with the project requirements will be brought to the attention of the general contractor’s construction superintendent, and the City’s representative immediately upon findings.

Final Reports
Upon completion of the parking structure pad, a final pad report will be provided detailing in-place density and moisture results for all tests taken. At the completion of the project, a final summary report will be prepared to document all our special inspection and materials testing services.

As-Needed Additional Consultation
If needed, we can provide other services that may be required during construction, such as reviewing structural design calculations, material submittals (in addition to those previously mentioned) and responding to requests for information (RFIs). If requested, these services will be invoiced at our approved fee rates with the City of Ontario.

ASSUMPTIONS
During our request for additional authorization preparation certain assumptions were required based on the available information provided. The following assumptions were made based on the provided information:

• No construction schedule, project plans, and/or project specifications were provided at the time of request for additional authorization preparation; • Work will be performed during normal business hours, typically between 6 AM and 5 PM; • Overtime services will not be required (more than eight hours per day, Saturday, Sunday, holidays, etc.);
• Work is subject to payment of California Prevailing Wages; • Laboratory and field testing will be performed is general accordance with ASTM standards; • The cost of any equipment (i.e. scaffold, scissor lifts, telescopic booms, ladders, shoring, etc.) to gain access to any area requiring inspection or sampling of materials is not included in this request for additional authorization;
• We are not providing fabrication shop inspection and/or batch plant inspection for asphalt concrete or Portland cement concrete;
• Out of town travel (more than 50 miles from the project site) and/or lodging will not be required;
• Preparation of supplemental reports and addendum letters and review of plans and specifications are not included in our fee; and
• Responses to review agencies or additional work that may be requested by reviewing agencies are not included.
717
MW180685.001P/ONT23P158153 Page 6 of 8 September 11, 2023 Copyright 2023 Kleinfelder www.kleinfelder.com
KLEINFELDER 620 S. Magnolia Bldg. G, Ontario, CA 91762 p | 909-.657.1716 f | 909.988.0185 It should be noted our services will not include: (1) supervision, direction, or acceptance of the contractor's work; (2) interpretation or modification of the project plans or specifications; (3) submittal of test results or reports to any regulatory agency (unless specifically requested by the client in writing); or (4) job site safety.

ESTIMATED FEE
We propose our services be compensated on a time-and-expense basis as shown in our attached fee estimate. For the scope of work outlined above, we will use the current approved rates associated with our on-call contract with the City of Ontario. We have estimated an approximate budget of $461,981.00 for this project, as reflected in the attached time-and-expense Table 1 - Fee Estimate. It should be noted that the fee rates shown in Table 1 - Fee Estimate are inclusive of standard equipment charges. We do not anticipate using equipment that is non-standard (coring equipment, rebar locators, or other non-standard equipment) for this project.

A “show-up” fee for scheduled services that are canceled after arrival if any, will incur a two-hour minimum charge. All field inspection and testing services are based on portal-to-portal from our local Ontario office and laboratory and will be billed in accordance with the Basis of Charges on the attached Table 1 - Fee Estimate.

It should be noted that the fees above do not anticipate overtime or double time work on the project. The rates associated with overtime and double time work are 1.5 and 2.0 times the listed hourly rates in Table 1 - Fee Estimate. Overtime for our services is defined as work on the project by a single person in excess of eight hours per day. Double time for our services is defined as time worked in excess of 12 hours per day (M-F), in excess of 12 hours per day on Saturday, and all time worked on Sundays and holidays. Overtime work can significantly impact our testing and inspection budget for the project. While we will be diligent in our attempts to keep overtime to a minimum, please be aware that contractor scheduling and performance are the primary causes for overtime work. Proficient contractor performance and scheduling minimizes additional testing and inspection time, consequently resulting in lower total fees. In the event conditions arise which are beyond our control, were unknown at the time this request for additional authorization was prepared, unanticipated based on the available information, or differ significantly from the assumptions shown below, we may need to revise our scope of work and estimated fees to complete the project. Should this occur, we will contact you for authorization before exceeding the project budget.

Our estimate is provided on a time-and-expense basis. It should be noted that our total fees on the project can fluctuate for a variety of unpredicted reasons beyond our control including weather conditions, the quality and performance of the construction materials used, and the contractor’s team, as well as the contractor’s approach and scheduling of construction sequences.

Jurisdictional requirements not identified at the outset of the project, or other unpredictable events that develop over the course of the project, can contribute to additional unplanned inspection or unanticipated engineering consultation not factored into our estimate.

AUTHORIZATION
We anticipate that the City of Ontario will sign the attached Request for Additional Authorization form referencing our Professional Services Agreement (Amendment Number 19). Provided that the approval for this request is consistent with previously negotiated terms and conditions, we will 718
MW180685.001P/ONT23P158153 Page 7 of 8 September 11, 2023 Copyright 2023 Kleinfelder www.kleinfelder.com
KLEINFELDER 620 S. Magnolia Bldg. G, Ontario, CA 91762 p | 909-.657.1716 f | 909.988.0185 execute and return an executed original copy to you for your records. If there is a need for any change in the scope of work or schedule described in this request for additional authorization or changes to the terms and conditions of those previously negotiated, please call us immediately.

Changes may require revision of the proposed fee, which will be communicated to you upon assessment of the requested changes' effect on the fee.

All information gathered by Kleinfelder is considered confidential and will be released only to those specified by the construction documents, or to others upon written authorization by the client, or as required by law.

Kleinfelder offers a range of assessment and engineering services to suit the varying needs of our clients. Although risk can never be eliminated, more detailed and extensive assessment or engineering yields more information, which may help understand and manage the degree of risk.

Since such detailed services involve greater expense, our clients participate in determining the level of service that provides adequate information for their purposes at an acceptable level of risk. Acceptance of this change order will indicate that the City of Ontario has reviewed the scope of services and determined that it does not need or want more services than are being proposed at this time. Any exceptions should be noted and may result in a change in fees.

LIMITATIONS
The safety of our employees is of paramount concern to Kleinfelder. You will be notified if the location of your project represents a potential safety concern to our employees. Unsafe conditions for fieldwork will require modification of our estimated scope of work and associated fees. We will advise you of the additional costs necessary to mitigate these unanticipated conditions, if applicable.

Our work will be performed in a manner consistent with that level of care and skill ordinarily exercised by other members of Kleinfelder’s profession practicing in the same locality, under similar conditions and at the date the services are provided. Our conclusions, opinion and recommendations will be based on a limited number of observations and data. It is possible that conditions could vary between or beyond the data evaluated. Kleinfelder makes no guarantee or warranty, express or implied, regarding the services, communication (oral or written), report, opinion, or instrument of service provided. Even with diligent monitoring, construction defects may occur. In all cases the contractor is solely responsible for the direction and quality of the work, adherence to plans and specifications, and repair of defects.

This request for additional authorization is valid for a period of 90 days from the date of the request for additional authorization unless a longer period is specifically required in which case that time frame will apply. This request for additional authorization was prepared specifically for the client and its designated representatives and may not be provided to others without Kleinfelder’s express permission.

The fee specified in this request for additional authorization is based upon the assumption that the site will be accessible to field personnel. If weather, access, or site conditions restrict our field operations, we may need to revise our fee estimate.

719
MW180685.001P/ONT23P158153 Page 8 of 8 September 11, 2023 Copyright 2023 Kleinfelder www.kleinfelder.com
KLEINFELDER 620 S. Magnolia Bldg. G, Ontario, CA 91762 p | 909-.657.1716 f | 909.988.0185

CLOSURE
We appreciate the opportunity to submit this request for additional authorization and look forward to working with you on this project. If there is a need for any change in the scope of service or schedule described in this request for additional authorization, or if you have any questions or require additional information, please call the undersigned at 909.657.1721.

Sincerely,

KLEINFELDER
Mike Dorsch Dany Hanna, PE
Project Manager Client Account Manager
Attachments:

Table 1 – Fee Estimate
Request for Additional Authorization Form
720
MW180685.001P/ONT23P158153 September 11, 2023
Copyright 2023 Kleinfelder www.kleinfelder.com
TABLE 1 – FEE ESTIMATE

721
Intersection of East D Street and North Sultana Avenue
PARKING STRUCTURE PROJECT Number of Visits Hours Each Visit Total Rate Cost (Days) (Hours) (Hours)
Special Inspection and Materials Testing Services
Soil/Asphalt Technician 40 8 320 $138.00 $44,160.00
Reinforced Concrete Inspector 130 8 1040 $138.00 $143,520.00 ACI Concrete Technician 40 8 320 $138.00 $44,160.00
PT Concrete Inspector (2 inspectors per stressing event) 44 8 352 $138.00 $48,576.00 Structural Masonry Inspector 30 8 240 $138.00 $33,120.00 Welding & Bolting Inspector 15 8 120 $138.00 $16,560.00 Sample Pick-up 50 2 100 $105.00 $10,500.00
ESTIMATED SUBTOTAL $340,596.00
Total Rate Cost
(Units/Ea.)
Laboratory Testing Services
Masonry Grout Compression (Assume 15 sets of 4) 60 $40.00 $2,400.00 Masonry Mortar Compression (Assume 6 sets of 4) 24 $40.00 $960.00 Masonry Prism Compression (Assume 6 sets of 3) 18 $150.00 $2,700.00 CMU Absorption and Received Moisture 9 $120.00 $1,080.00 CMU Compression 9 $125.00 $1,125.00
CMU Dimension Verification 9 $55.00 $495.00
Non-Shrink Grout Compression (assume 3 sets of 3) 9 $40.00 $360.00 Concrete Compression (Assume 85 sets of 5) 425 $40.00 $17,000.00 Modified Proctor 8 $290.00 $2,320.00
Modified Proctor Oversize Correction 4 $90.00 $360.00
Metal Bend 50 $55.00 $2,750.00
Rebar Tensile, up to No. 11 50 $120.00 $6,000.00
PT Strand Tensile 15 $205.00 $3,075.00
Bolt Assembly Suite (Bolt, Nut, Washer) 3 $285.00 $855.00 Hveem Stability without Compaction 2 $220.00 $440.00
Unit Weight, Hveem Method 2 $370.00 $740.00
AC Content by Extraction 2 $260.00 $520.00
Gradation of Extracted Aggregate 2 $150.00 $300.00
ESTIMATED SUBTOTAL $43,480.00
Total Rate Cost
Project Management & Administration (Hours/Units)
Project Manager (Planning, Project Management, Review of Project Documents, Meetings) 85 $200.00 $17,000.00 Geotechnical Engineer (Review, Consultation, Meetings) 20 $210.00 $4,200.00 Project Administrator 45 $135.00 $6,075.00
Project Coordination 30 $105.00 $3,150.00
Parking Structure Pad Report (Lump Sum) 1 $2,000.00 $2,000.00 Final Observation and Testing Summary Report (Lump Sum) 1 $3,000.00 $3,000.00 ESTIMATED SUBTOTAL $35,425.00
PARKING STRUCTURE PROJECT - ESTIMATED TOTAL FEE $419,501.00 STORM DRAIN INSTALLATION PROJECT Number of Visits Hours Each Visit Total Rate Cost (Days) (Hours) (Hours)
Materials Testing Services
Soil/Asphalt Technician 30 8 240 $138.00 $33,120.00
ESTIMATED SUBTOTAL $33,120.00
Total Rate Cost
(Units/Ea.)
Laboratory Testing Services
Modified Proctor 3 $290.00 $870.00
Sieve Analysis (Coarse & Fine) 1 $200.00 $200.00
Sand Equivalent Value 2 $180.00 $360.00
R-Value 1 $390.00 $390.00
Los Angeles Abrasion, Small Aggregate 1 $240.00 $240.00 Hveem Stability without Compaction 2 $220.00 $440.00
Unit Weight, Hveem Method 2 $370.00 $740.00
AC Content by Extraction 2 $260.00 $520.00
Gradation of Extracted Aggregate 2 $150.00 $300.00
ESTIMATED SUBTOTAL $4,060.00
Total Rate Cost
Project Management & Administration (Hours/Units)
Project Manager (Planning, Project Management, Review of Project Documents, Meetings) 10 $200.00 $2,000.00 Geotechnical Engineer (Review, Consultation, Meetings) 4 $210.00 $840.00 Project Administrator 8 $135.00 $1,080.00
Project Coordination 6 $105.00 $630.00
Final Observation and Testing Summary Report (Lump Sum) 1 $750.00 $750.00 ESTIMATED SUBTOTAL $5,300.00
STORM DRAIN INSTALLATION PROJECT - ESTIMATED TOTAL FEE $42,480.00 PARKING STRUCTURE & STORM DRAIN INSTALLATION PROJECT - ESTIMATED TOTAL FEE $461,981.00 (Portal-to-Portal from Kleinfelder's Ontario Office)

HOURS WORKED HOURS / PREMIUMS BILLED
Show up / work cancelled 2
0 - 8 Actual Hours Worked
8 - 12 and Saturday Time and One-Half
Greater than 12, Sundays, and Holidays Double Time
Table 1 - Fee Estimate
Special Inspection and Materials Testing Services
Parking Structure & Storm Drain Installation Project
Ontario, California 91764
This fee estimate assumes that prevailing wage laws apply to the subject project

BASIS OF CHARGES
MW180685.001P/ONT23P158153
Copyright 2023 Kleinfelder Page 1 of 1 September 11, 2023 722
MW180685.001P/ONT23P158153 September 11, 2023
Copyright 2023 Kleinfelder www.kleinfelder.com

REQUEST FOR ADDITIONAL AUTHORIZATION FORM
723
Request for Additional Authorization
Issued pursuant to the Professional Service Agreement and Amendment No. 19 by and between the City of Ontario and Kleinfelder, Inc. (Kleinfelder).

Client Name: City of Ontario
Kleinfelder Project No: 20230123.002A
Project Name: Proposed Parking Structure Project (D Street Parking Structure) Work Order Type: (Check One)
Time-and-Materials
Fixed-Price
Kleinfelder Office: Ontario
Kleinfelder Contact Name: Mike Dorsch

1. SCOPE OF WORK: Added special inspection and materials testing services. See attached document for a detailed description of proposed services.

2. LOCATION/CLIENT FACILITY INVOLVED: Intersection at East D Street and North Sultana Avenue in the City of Ontario.

3. PERIOD OF PERFORMANCE: As requested.

4. AUTHORIZED FUNDING: See below.
• Original Project Cost: $35,074.00
• Requested Additional Authorization Fee: $461,981.00
• New Project Total: $497,055.00

5. SPECIAL PROVISIONS: N/A
NOTICE TO PROCEED IS GIVEN ON (DATE): September 11, 2023 CLIENT: CITY OF ONTARIO KLEINFELDER, INC.:

By: ___________________________________ By: __________________________________ Printed Name: Printed Name: Mike Dorsch
Title: Title: Project Manager
Address: Address: 620 S. Magnolia Avenue, Building G
Ontario, CA 91762
724
Department: Public Works
Prepared By: Gil H Mars
Staff Member Presenting:

Tito Haes, Executive Director Public Works
Reviewed By: Bonnie Tam, Andrea Ampig
Approved By:

Submitted To: Council/OHA
Approved: _______________________________
Continued To: ___________________________
Denied: __________________________________
Item No: 16
SUBJECT: AN AMENDMENT TO THE ON-CALL DESIGN SERVICES AGREEMENT WITH ROBERT BORDERS AND ASSOCIATES FOR THE 208 EMPORIA 1ST FLOOR OFFICE

RENOVATION PROJECT

CITY OF ONTARIO
Agenda Report
November 21, 2023
SECTION:

CONSENT CALENDAR
RECOMMENDATION: That the City Council take the following actions:

A. Authorize the City Manager or his designee to execute Amendment No. 19 to the On-Call Design Services Agreement with Robert Borders and Associates, of Costa Mesa, California, for the 208 Emporia 1st Floor Office Renovation Project in the amount of $29,620 for a total notto-exceed contract amount of $652,462; and B. Authorize the City Manager or his designee to execute all documents required for the completion of the project including, but not limited to, contracts, agreements, assessments, easements, reduction of retention accounts, and filing a notice of completion at the conclusion of all construction related activities.

THE FOLLOWING COUNCIL GOALS ARE BEING ACHIEVED:

Invest in the City's Infrastructure (Water, Streets, Sewers, Parks, Storm Drains and Public Facilities)
FISCAL IMPACT: The Fiscal Year 2023-24 Adopted Budget includes appropriations in the General Fund for the 208 Emporia 1st Floor Office Renovation Project. The proposed Amendment will increase the contract amount by $29,620 for a total not-to-exceed contract amount of $652,462. The total contract amount of $652,462 includes on-call work performed for various citywide projects.

BACKGROUND & ANALYSIS: There is an increased demand for Community Improvement and Code Enforcement services as the City has grown. This has led to a need for increased staff support at 208 Emporia 1st floor. To effectively house and support the increased personnel, cubicle workstations and an office are planned to be built in the existing space. Robert Borders and Associates will facilitate the redesign of the existing space and provide space planning services, preparation of construction drawings, and assistance during the bidding phase for the construction for the project.
725
46700.00100\33287662.1

BB&K 2020
AMENDMENT NO. 19 TO THE DESIGN SERVICES AGREEMENT

BETWEEN THE CITY OF ONTARIO AND

ROBERT BORDERS AND ASSOCIATES

1. Parties and Date.

This Amendment No. 19 to the Agreement (as defined herein) is made and entered as of ____________, by and between the City of Ontario (“City”) and ROBERT BORDERS AND ASSOCIATES, a CORPORATION, (“CONSULTANT”). City and Consultant are sometimes individually referred to as “Party” and collectively as “Parties.”

2. Recitals.

2.1 Agreement. The City and Consultant have entered into an agreement entitled “DESIGN SERVICES AGREEMENT” dated October 17, 2023. (“Agreement”).

2.2 Amendment Purpose. The City and Consultant desire to amend the Agreement to revise the scope of services for D&C23-008 208 Emporia 1st Floor project set forth in Amendment No. 19 – Attachment “A” and increase the not to exceed compensation amount by TWENTY NINE THOUSAND SIX HUNDRED AND TWENTY DOLLARS ($29,620.00). The Parties have heretofore entered into that Amendment No. 1 dated March 15, 2020, Amendment No. 2 dated June 22, 2020, Amendment No. 3 dated November 19, 2020, Amendment No. 4 dated December 5, 2020, Amendment No. 5 dated January 15, 2021, Amendment No. 6 dated April 6, 2021, Amendment No.7 dated August 11, 2021, Amendment No. 8 dated September 30, 2021, Amendment No. 9 dated September 30, 2021, Amendment No. 10 dated February 1, 2022, Amendment No. 11 dated October 1, 2022, Amendment No. 12 dated January 5, 2023, Amendment No. 13 dated May 17, 2023, Amendment No. 14 dated June 20, 2023, Amendment No. 15 dated June 20, 2023, Amendment No. 16 dated August 15, 2023, and Amendment No. 17 dated September 19, 2023 and Amendment No. 18 going to council November 7, 2023.

2.3 Amendment Authority. This Amendment No. 19 is authorized pursuant to Section

3.10.1 of the Agreement.
726
46700.00100\33287662.1

BB&K 2020

3. Terms.

3.1 Amendment. Section 3.10.1 of the Agreement is hereby amended in its entirety to read as follows:
“Section 3.10.1 Consultant’s Compensation for Basic Services.

City shall pay to Consultant for the performance of all Services rendered under this Agreement, with the total not to exceed amount of Six Hundred Fifty-Two Thousand Four Hundred Sixty-Two Dollars ($652,462) (“Total Compensation”). This total compensation amount shall be based upon, and may be adjusted according to the fee schedule and related terms and conditions attached hereto as “Exhibit B” and incorporated herein by reference. The total compensation, as may be adjusted upon mutual agreement, shall constitute complete and adequate payment for Services under this Agreement.”
Exhibit A is hereby deleted in its entirety and replaced with Attachment A attached hereto and incorporated herein by reference.

3.2 Continuing Effect of Agreement. Except as amended by this Amendment No. 19, all other provisions of the Agreement remain in full force and effect and shall govern the actions of the parties under this Amendment No. 19. From and after the date of this Amendment No. 19, whenever the term “Agreement” appears in the Agreement, it shall mean the Agreement as amended by this Amendment No 19.

3.3 Adequate Consideration. The Parties hereto irrevocably stipulate and agree that they have each received adequate and independent consideration for the performance of the obligations they have undertaken pursuant to this Amendment No. 19.

3.4 Severability. If any portion of this Amendment No. 19 is declared invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect.

3.5 Integration. This Amendment represents the entirety of the Parties’ understanding relating to the subject of this Amendment, including written or verbal communications between the Parties, which shall have no relevance unless expressly incorporated herein. This is an integrated amendment.
[SIGNATURES ON FOLLOWING PAGE]
727
46700.00100\33287662.1

BB&K 2020
SIGNATURE PAGE FOR AMENDMENT NO. _19__ TO DESIGN SERVICES

AGREEMENT BETWEEN THE CITY OF ONTARIO

AND ROBERT BORDERS AND ASSOCIATES
IN WITNESS WHEREOF, the Parties have entered into this Amendment No. 19 as of the day and year first above written.

CITY OF ONTARIO ROBERT BORDERS AND ASSOCIATES
By:

Its:

Printed Name:

By:

Its:

Printed Name:
[If Corporation, TWO SIGNATURES,
President OR Vice President AND Secretary
OR Treasurer REQUIRED]
Approved By:

Tito Haes
Executive Director Public Works
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:

City Clerk
728
Department: Human Resources
Prepared By: Amanda Elias
Staff Member Presenting:

Angela C. Lopez, Executive Director Human
Resources
Approved By:

Submitted To: Council/OHA
Approved: _______________________________
Continued To: ___________________________
Denied: __________________________________
Item No: 17
SUBJECT: AWARD OF PROFESSIONAL SERVICE AGREEMENTS WITH TEMPORARY STAFFING

AGENCIES FOR AS-NEEDED TEMPORARY STAFFING REQUIREMENTS

CITY OF ONTARIO
Agenda Report
November 21, 2023
SECTION:

CONSENT CALENDAR
RECOMMENDATION: That the City Council takes the following actions:

A. Approve and authorize the City Manager or his designee to execute a three-year Professional Services Agreement with 22nd Century Technologies, Inc. of Somerset, New Jersey, for on-call, as-needed temporary staffing requirements for a total not-to-exceed contract amount of $1,300,000;
B. Approve and authorize the City Manager or his designee to execute a three-year Professional Services Agreement with AppleOne, Inc. of Torrance, California, for on-call, as-needed temporary staffing requirements for a total not-to-exceed contract amount of $700,000; C. Approve and authorize the City Manager or his designee to execute a three-year Professional Services Agreement with Enterprise Solutions, Inc. of Santa Clara, California, for on-call, asneeded temporary staffing requirements for a total not-to-exceed contract amount of $700,000;
D. Approve and authorize the City Manager or his designee to execute a three-year Professional Services Agreement with Resource Logistics, Inc. of East Brunswick, New Jersey, for on-call, asneeded temporary staffing requirements for a total not-to-exceed contract amount of $700,000;
E. Approve and authorize the City Manager or his designee to execute a three-year Professional Services Agreement with SoftHQ, Inc. of San Diego, California, for on-call, as-needed temporary staffing requirements for a total not-to-exceed contract amount of $1,300,000; F. Approve and authorize the City Manager or his designee to execute a three-year Professional Services Agreement with Staffing Network, LLC of Oakbrook, Illinois, for on-call, as-needed temporary staffing requirements for a total not-to-exceed contract amount of $1,300,000; and
G. Authorize a total aggregate not-to-exceed three-year contract amount of $6,000,000 with 22nd Century Technologies, Inc., AppleOne, Inc., Enterprise Solutions, Inc., Resource Logistics, Inc., SoftHQ, Inc., Staffing Network, LLC.
729
THE FOLLOWING COUNCIL GOALS ARE BEING ACHIEVED:

Operate in a Businesslike Manner
FISCAL IMPACT: The proposed agreements for the six (6) temporary staffing agencies have a total not-to-exceed amount for year one (1) of $2,000,000. The total not-to-exceed amount for year two (2) is $2,000,000. The total not-to-exceed amount for year three (3) is of $2,000,000 for a total of not-to-exceed contract amount of $6,000,000. The City is not obligated to expend funds or guarantee service levels for the selected staffing agencies. Actual expenditures may vary due to unforeseen vacancies and workload changes throughout the City. Each City department will assume the fiscal responsibility of actively monitoring their budgets while still meeting staffing needs effectively. This action ensures that departmental expenditures related to temporary staffing services remain within the agency’s annual budgets.

BACKGROUND & ANALYSIS: The City spent a total of $1,644,000 during Fiscal Year 2022-2023 on temporary staffing services. These costs were split among two (2) temporary staffing agencies and were incurred by various City departments utilizing the services. The City requires the ongoing use of temporary staffing agencies to fulfill operational needs for short-term increases in service demands, extended employee absences due to illness, and to fill vacancies in critical positions while recruitments are in progress. On January 30, 2023, the City solicited proposals for City-Wide Temporary Staffing Services. The purpose of the Request for Proposals (RFP) was to develop an approved list of temporary staffing agencies that will work directly with the City to provide quality temporary personnel in a timely manner at established rates. As of March 1, 2023, the City received 42 proposals in response to the RFP. The evaluation committee, comprised of staff from the Human Resources, Public Works, and Community Life & Culture Agencies, recommended Agreements with six (6) of the 42 temporary staffing agencies. The proposals were evaluated on the following criteria:

1. Clarity and conformance of proposal to RFP

2. Content of the proposal

3. Proposer’s experience and performance

4. Staffing Resources

5. Fee proposal

6. References' comments
Establishing Agreements with multiple temporary staffing agencies is recommended to ensure timely and high-quality services. The non-exclusive Agreements will be for a period of three years with the option to extend any or all the Agreements for two (2) successive one (1) year extensions, subject to budget appropriations. The City may terminate any of these Agreements with seven (7) days written notice.

The table below displays the mark-up rates charged by temporary staffing agencies for different skill categories. These rates will remain fixed for the duration of the Agreements. 730
Clerical/Admin. Office
Staff
Information
Technology
Light Industrial
22nd Century
Technologies, Inc.
30% 30% 30%
AppleOne, Inc. 48% 55% N/A
Enterprise Solutions,
Inc.
40% 40% N/A
Resource Logistics, Inc. 32% 38% N/A
SoftHQ, Inc. 40% 40% 40%
Staffing Network, LLC 47% 47% 52%
*Light Industrial temporary positions include maintenance worker, custodial (janitor), and integrated waste collector.
731
46700.00100\40935195.1
BB&K (2023) Exhibit “C”-1 PROFESSIONAL SERVICES AGREEMENT

CITY OF ONTARIO

PROFESSIONAL SERVICES AGREEMENT

1. PARTIES AND DATE.

This Agreement is made and entered as of ____________, by and between the City of Ontario, a municipal corporation organized under the laws of the State of California with its principal place of business at 303 East “B” Street, Ontario, California 91764-4196, County of San Bernardino, State of California ("City") and 22nd Century Technologies, Inc., a Corporation, with its principal place of business at 1 Executive Drive, Suite 285, Somerset, NJ 08873 ("Consultant"). City and Consultant are sometimes individually referred to herein as "Party" and collectively as "Parties."

2. RECITALS.

2.1 Consultant.

Consultant desires to perform and assume responsibility for the provision of certain professional services required by the City on the terms and conditions set forth in this Agreement.

Consultant represents that it is experienced in providing temporary staffing services to public clients, is licensed in the State of California, and is familiar with the plans of City.

2.2 Project.

City desires to engage Consultant to render such professional services for temporary staffing services for the City on an as-needed basis (“Project”) as set forth in this Agreement.

3. TERMS.

3.1 Scope of Services and Term.

3.1.1 General Scope of Services. Consultant promises and agrees to furnish to the City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the professional temporary staffing consulting services necessary for the Project ("Services"). The Services are more particularly described in Exhibit "A" attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordance with, this Agreement, the exhibits attached hereto and incorporated PAUL S. LEON
MAYOR

DEBRA PORADA

MAYOR PRO TEM
ALAN D. WAPNER
JIM W. BOWMAN

RUBEN VALENCIA

COUNCIL MEMBERS

SHEILA MAUTZ

CITY CLERK
JAMES R. MILHISER

TREASURER

SCOTT OCHOA

CITY MANAGER
732
46700.00100\40935195.1
BB&K (2023) -2- PROFESSIONAL SERVICES AGREEMENT
herein by reference, and all applicable local, state and federal laws, rules and regulations.

3.1.2 Term. The term of this Agreement shall be from November 21, 2023 to November 21, 2026, unless earlier terminated as provided herein. The City shall have the unilateral option, at its sole discretion, to renew this Agreement automatically for no more than two (2) additional one-year terms, unless earlier terminated as provided herein. Consultant shall complete the Services within the term of this Agreement and shall meet any other established schedules and deadlines. The Parties may, by mutual, written consent, extend the term of this Agreement if necessary to complete the Services.

3.2 Compensation.

3.2.1 Compensation. Consultant shall receive compensation, including authorized reimbursements, for all Services rendered under this Agreement at the rates set forth in Exhibit "C" attached hereto and incorporated herein by reference. The total compensation shall not exceed One Million Three Hundred Thousand Dollars and Zero Cents ($1,300,000) without written approval of the City Council or City Manager, as applicable. Extra Work may be authorized, as described below, and if authorized, will be compensated at the rates and manner set forth in this Agreement.

3.2.2 Payment of Compensation. Consultant shall submit to City a monthly invoice which indicates work completed and hours of Services rendered by Consultant. The invoice shall describe the amount of Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the invoice.

City shall, within 30 days of receiving such invoice, review the invoice and pay all non-disputed and approved charges. If the City disputes any of Consultant's fees, the City shall give written notice to Consultant within thirty (30) days of receipt of an invoice of any disputed fees set forth therein. Payment shall not constitute acceptance of any Services completed by Consultant. The making of final payment shall not constitute a waiver of any claims by the City for any reason whatsoever.

3.2.3 Reimbursement for Expenses. Consultant shall not be reimbursed for any expenses unless authorized in writing by City, or included in Exhibit "C" of this Agreement.

3.2.4 Extra Work. At any time during the term of this Agreement, City may request that Consultant perform Extra Work. As used herein, "Extra Work" means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement.

Consultant shall not perform, nor be compensated for, Extra Work without written authorization from the City.

3.3 Responsibilities of Consultant.

3.3.1 Independent Contractor; Control and Payment of Subordinates. The Services shall be performed by Consultant or under its supervision. Consultant will determine the means, methods and details of performing the Services subject to the requirements of this Agreement. City retains Consultant on an independent contractor basis and not as an employee.

Any personnel performing the Services on behalf of Consultant shall not be employees of City and shall at all times be under Consultant's exclusive direction and control. Neither City, or any of its officials, officers, directors, employees or agents shall have control over the conduct of 733
46700.00100\40935195.1
BB&K (2023) -3- PROFESSIONAL SERVICES AGREEMENT
Consultant or any of Consultants officers, employees or agents, except as set forth in this Agreement. Consultant shall pay all wages, salaries, and other amounts due such personnel in connection with their performance of Services under this Agreement and as required by law.

Consultant shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers' compensation insurance.

3.3.2 Schedule of Services. Consultant shall perform the Services in a prompt and timely manner and in accordance with the Schedule of Services set forth in Exhibit "B" attached hereto and incorporated herein by reference. Consultant represents that it has the professional and technical personnel required to perform the Services expeditiously. Upon request of City, Consultant shall provide a more detailed schedule of anticipated performance to meet the Schedule of Services.

3.3.3 Conformance to Applicable Requirements. All work prepared by Consultant shall be subject to the approval of City.

3.3.4 Substitution of Key Personnel. Consultant has represented to City that certain key personnel will perform and coordinate the Services under this Agreement. Should one or more of such personnel become unavailable, Consultant may substitute other personnel of at least equal competence upon written approval of City. In the event that City and Consultant cannot agree as to the substitution of key personnel, City shall be entitled to terminate this Agreement for cause. The key personnel for performance of this Agreement are as follows: Isha Sharma, Contract Manager.

3.3.5 City's Representative. The City hereby designates Angela Lopez, Executive Director Human Resources/Risk Management, or his/her designee, to act as its representative in all matters pertaining to the administration and performance of this Agreement ("City's Representative"). City's Representative shall have the power to act on behalf of the City for review and approval of all products submitted by Consultant but not the authority to enlarge the Scope of Services or change the total compensation due to Consultant under this Agreement.

The City Manager shall be authorized to act on City's behalf and to execute all necessary documents which enlarge the Scope of Services or change the Consultant's total compensation subject to the provisions contained in this Agreement. Consultant shall not accept direction or orders from any person other than the City Manager, City's Representative or his/her designee.

3.3.6 Consultant's Representative. Consultant hereby designates Isha Sharma, Contract Manager, or his/her designee, to act as its representative for the performance of this Agreement ("Consultant's Representative"). Consultant's Representative shall have full authority to represent and act on behalf of the Consultant for all purposes under this Agreement. The Consultant's Representative shall supervise and direct the Services, using his/her best skill and attention, and shall be responsible for all means, methods, techniques, sequences, and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.

3.3.7 Coordination of Services. Consultant agrees to work closely with City staff in the performance of Services and shall be available to City's staff, consultants and other staff at all reasonable times.

3.3.8 Standard of Care; Performance of Employees. Consultant shall perform all 734
46700.00100\40935195.1
BB&K (2023) -4- PROFESSIONAL SERVICES AGREEMENT
Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals in the same discipline in the State of California. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services. Consultant warrants that all employees and subconsultants shall have sufficient skill and experience to perform the Services assigned to them. Consultant represents that it, its employees and subconsultants have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services, and that such licenses and approvals shall be maintained throughout the term of this Agreement. Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant's failure to comply with the standard of care provided for herein. Any employee of the Consultant or its subconsultants who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed from the Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.

3.3.9 Period of Performance.

3.3.9.1 Consultant shall perform and complete all Services under this Agreement within the term set forth in Section 3.1.2 above (“Performance Time”). Consultant shall also perform the Services in strict accordance with any completion schedule or Project milestones described in Exhibits “A” or “B” attached hereto, or which may be separately agreed upon in writing by the City and Consultant (“Performance Milestones”). Consultant agrees that if the Services are not completed within the aforementioned Performance Time and/or pursuant to any such Performance Milestones developed pursuant to provisions of this Agreement, it is understood, acknowledged and agreed that the City will suffer damage.

3.3.9.2 Neither City nor Consultant shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the non-performing Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Consultant and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the services and Agreement.

3.3.9.3 Should a Force Majeure Event occur, the non-performing Party shall, within a reasonable time of being prevented from performing, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events and/or delays, regardless of the Party responsible for the delay, shall not entitle Consultant to any additional compensation. 735
46700.00100\40935195.1
BB&K (2023) -5- PROFESSIONAL SERVICES AGREEMENT
Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement.

3.3.10 Laws and Regulations; Employee/Labor Certification.

3.3.10.1 Compliance with Laws. Consultant shall keep itself fully informed of and in compliance with all local, state and federal laws, rules and regulations in any manner affecting the performance of the Project or the Services, including all Cal/OSHA requirements, and shall give all notices required by law. Consultant shall be liable for all violations of such laws and regulations in connection with the Services and this Agreement. All violations of such laws and regulations shall be grounds for the City to terminate the Agreement for cause.

3.3.10.2 Employment Eligibility; Consultant. Consultant certifies that it fully complies with all requirements and restrictions of state and federal law respecting the employment of undocumented aliens, including, but not limited to, the Immigration Reform and Control Act of 1986, as may be amended from time to time and shall require all subconsultants and sub-subconsultants to comply with the same. Consultant certifies that it has not committed a violation of any such law within the five (5) years immediately preceding the date of execution of this Agreement, and shall not violate any such law at any time during the term of the Agreement.

3.3.10.3 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subconsultant, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination. Consultant shall also comply with all relevant provisions of City's Minority Business Enterprise program, Affirmative Action Plan or other related programs or guidelines currently in effect or hereinafter enacted.

3.3.10.4 Air Quality. To the extent applicable, Consultant must fully comply with all applicable laws, rules and regulations in furnishing or using equipment and/or providing services, including, but not limited to, emissions limits and permitting requirements imposed by the South Coast Air Quality Management District (SCAQMD) and/or California Air Resources Board (CARB). Consultant shall indemnify City against any fines or penalties imposed by SCAQMD, CARB, or any other governmental or regulatory agency for violations of applicable laws, rules and/or regulations by Consultant, its subconsultants, or others for whom Consultant is responsible under its indemnity obligations provided for in this Agreement.

3.3.10.5 Water Quality Management and Compliance. Consultant shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Services including, without limitation, all applicable provisions of the City’s ordinances regulating water quality and storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251, et seq.); the California Porter-Cologne Water Quality Control Act (Water Code § 13000 et seq.); and any and all regulations, policies, or permits issued pursuant to any such authority. Consultant must additionally comply with the lawful requirements of the City, and any other municipality, drainage district, or other local agency with jurisdiction over the location where the Services are to be conducted, regulating water quality and storm water discharges. City may seek damages from Consultant for delay in completing the Services caused by Consultant’s 736
46700.00100\40935195.1
BB&K (2023) -6- PROFESSIONAL SERVICES AGREEMENT
failure to comply with the laws, regulations and policies described in this Section, or any other relevant water quality law, regulation, or policy.

3.3.10.6 Safety. Consultant shall execute and maintain its work so as to avoid injury or damage to any person or property. In carrying out its Services, the Consultant shall at all times be in compliance with all applicable local, state and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of employees appropriate to the nature of the work and the conditions under which the work is to be performed.

3.3.11 Insurance.

3.3.11.1 Time for Compliance. Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurance required under this section. Failure to provide and maintain all required insurance shall be grounds for the City to terminate this Agreement for cause.

3.3.11.2 Types of Insurance Required. As a condition precedent to the effectiveness of this Agreement for work to be performed hereunder, and without limiting the indemnity provisions of the Agreement, the Consultant, in partial performance of its obligations under such Agreement, shall procure and maintain in full force and effect during the term of the Agreement the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Consultant agrees to amend, supplement or endorse the policies to do so.
(A) Commercial General Liability: Commercial General Liability Insurance which affords coverage at least as broad as Insurance Services Office "occurrence" form CG 00 01, or the exact equivalent, with limits of not less than $2,000,000 per occurrence and no less than $4,000,000 in the general aggregate. Defense costs shall be paid in addition to the limits. The policy shall contain no endorsements or provisions (1) limiting coverage for contractual liability; (2) excluding coverage for claims or suits by one insured against another (cross-liability); (3) products/completed operations liability; or (4) containing any other exclusion(s) contrary to the terms or purposes of this Agreement. (B) Automobile Liability Insurance: Automobile Liability Insurance with coverage at least as broad as Insurance Services Office Form CA 00 01 covering "Any Auto" (Symbol 1), or the exact equivalent, covering bodily injury and property damage for all activities with limits of not less than $2,000,000 combined limit for each occurrence. (C) Workers' Compensation: Workers' Compensation
Insurance, as required by the State of California and Employer's Liability Insurance with a limit of not less than $1,000,000 per accident for bodily injury and disease. (D) Professional Liability (Errors & Omissions): Professional Liability insurance or Errors & Omissions insurance appropriate to Consultant’s profession with limits of not less than $2,000,000. Covered professional services shall specifically include all work to be performed under the Agreement and delete any exclusions that may potentially affect the work to be performed (for example, any exclusions relating to lead, asbestos, pollution, testing, underground storage tanks, laboratory analysis, soil work, etc.). If coverage is written on 737
46700.00100\40935195.1
BB&K (2023) -7- PROFESSIONAL SERVICES AGREEMENT
a claims-made basis, the retroactive date shall precede the effective date of the initial Agreement and continuous coverage will be maintained or an extended reporting period will be exercised for a period of at least five (5) years from termination or expiration of this Agreement.

3.3.11.3 Insurance Endorsements. Required insurance policies shall contain the following provisions, or Consultant shall provide endorsements on forms approved by the City to add the following provisions to the insurance policies:
(A) Commercial General Liability: (1) Additional Insured: The City, its officials, officers, employees, agents, and volunteers shall be additional insureds with regard to liability and defense of suits or claims arising out of the performance of the Agreement.

Additional Insured Endorsements shall not (1) be restricted to "ongoing operations"; (2) exclude "contractual liability"; (3) restrict coverage to "sole" liability of Consultant; or (4) contain any other exclusions contrary to the terms or purposes of this Agreement. For all policies of Commercial General Liability insurance, Consultant shall provide endorsements in the form of ISO CG 20 10 10 01 and 20 37 10 01 (or endorsements providing the exact same coverage) to effectuate this requirement. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (B) Automobile Liability: (1) Additional Insured: The City, its directors, officials, officers, employees, agents, and volunteers shall be covered as additional insureds with respect to the ownership, operation, maintenance, use, loading or unloading of any auto owned, leased, hired or borrowed by the Vendor or for which the Vendor is responsible. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium.
(C) Professional Liability (Errors & Omissions): 1) Cancellation:

Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) This insurance shall be written on a policy form coverage specifically designed to protect against acts, errors or omissions of the Consultant. “Covered Professional Services” as designated in the policy must specifically include work performed under this Agreement. The policy must “pay on behalf of” the insured and include a provision establishing the insurer’s duty to defend.
(D) Workers' Compensation: (1) Cancellation: Required
insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) Waiver of Subrogation: A waiver of subrogation stating that the insurer waives all rights of subrogation against the City, its officials, officers, employees, agents, and volunteers.

3.3.11.4 Primary and Non-Contributing Insurance. All policies of Commercial General Liability and Automobile Liability insurance shall be primary and any other insurance, deductible, or self-insurance maintained by the City, its officials, officers, employees, agents, or volunteers shall not contribute with this primary insurance. Policies shall contain or be endorsed to contain such provisions.
738
46700.00100\40935195.1
BB&K (2023) -8- PROFESSIONAL SERVICES AGREEMENT

3.3.11.5 Waiver of Subrogation. All required insurance coverages, except for the professional liability coverage, shall contain or be endorsed to waiver of subrogation in favor of the City, its officials, officers, employees, agents, and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these specifications to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants.

3.3.11.6 Deductibles and Self-Insured Retentions. Any deductible or selfinsured retention must be approved in writing by the City and shall protect the City, its officials, officers, employees, agents, and volunteers in the same manner and to the same extent as they would have been protected had the policy or policies not contained a deductible or self-insured retention.

3.3.11.7 Evidence of Insurance. The Consultant, concurrently with the execution of the Agreement, and as a condition precedent to the effectiveness thereof, shall deliver either certified copies of the required policies, or original certificates on forms approved by the City, together with all endorsements affecting each policy. Required insurance policies shall not be in compliance if they include any limiting provision or endorsement that has not been submitted to the City for approval. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf. At least fifteen (15 days) prior to the expiration of any such policy, evidence of insurance showing that such insurance coverage has been renewed or extended shall be filed with the City. If such coverage is cancelled or reduced and not replaced immediately so as to avoid a lapse in the required coverage, Consultant shall, within ten (10) days after receipt of written notice of such cancellation or reduction of coverage, file with the City evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies.

3.3.11.8 Acceptability of Insurers. Each such policy shall be from a company or companies with a current A.M. Best's rating of no less than A:VII and authorized to transact business of insurance in the State of California, or otherwise allowed to place insurance through surplus line brokers under applicable provisions of the California Insurance Code or any federal law.

3.3.11.9 Enforcement of Agreement Provisions (non estoppel).

Consultant acknowledges and agrees that actual or alleged failure on the part of the City to inform Consultant of non-compliance with any requirement imposes no additional obligation on the City nor does it waive any rights hereunder.

3.3.11.10 Requirements Not Limiting. Requirement of specific coverage or minimum limits contained in this Section are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance.

3.3.11.11 Additional Insurance Provisions
(A) The foregoing requirements as to the types and limits of insurance coverage to be maintained by Consultant, and any approval of said insurance by the City, is not intended to and shall not in any manner limit or qualify the liabilities and obligations 739
46700.00100\40935195.1
BB&K (2023) -9- PROFESSIONAL SERVICES AGREEMENT
otherwise assumed by the Consultant pursuant to this Agreement, including but not limited to, the provisions concerning indemnification.
(B) If at any time during the life of the Agreement, any policy of insurance required under this Agreement does not comply with these specifications or is canceled and not replaced, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Consultant or City will withhold amounts sufficient to pay premium from Consultant payments. In the alternative, City may cancel this Agreement.
(C) The City may require the Consultant to provide complete copies of all insurance policies in effect for the duration of the Project. (D) Neither the City nor any of its officials, officers, employees, agents or volunteers shall be personally responsible for any liability arising under or by virtue of this Agreement.
(E) The limits set forth herein shall apply separately to each insured against whom claims are made or suits are brought, except with respect to the limits of liability. Further the limits set forth herein shall not be construed to relieve the Consultant from liability in excess of such coverage, nor shall it limit the Consultant’s indemnification obligations to the City and shall not preclude the City from taking such other actions available to the City under other provisions of the Agreement or law.
(F) Consultant shall report to the City, in addition to Consultant’s insurer, any and all insurance claims submitted by Consultant in connection with the Services under this Agreement.

3.3.11.12 Insurance for Subconsultants. Consultant shall include all subconsultants engaged in any work for Consultant relating to this Agreement as additional insureds under the Consultant's policies, or the Consultant shall be responsible for causing subconsultants to purchase the appropriate insurance in compliance with the terms of these Insurance Requirements, including adding the City, its officials, officers, employees, agents, and volunteers as additional insureds to the subconsultant's policies. All policies of Commercial General Liability insurance provided by Consultant’s subconsultants performing work relating to this Agreement shall be endorsed to name the City, its officials, officers, employees, agents and volunteers as additional insureds using endorsement form ISO CG 20 38 04 13 or an endorsement providing equivalent coverage. Consultant shall not allow any subconsultant to commence work on any subcontract relating to this Agreement until it has received satisfactory evidence of subconsultant’s compliance with all insurance requirements under this Agreement, to the extent applicable. The Consultant shall provide satisfactory evidence of compliance with this section upon request of the City.

3.4 Labor Code Requirements.

3.4.1 Prevailing Wages. Consultant is aware of the requirements of California Labor Code Section 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., ("Prevailing Wage Laws"), which require the payment of prevailing wage rates and the performance of other requirements on "public works" and "maintenance" projects. If the Services are being performed as part of an applicable "public works" or 740
46700.00100\40935195.1
BB&K (2023) -10- PROFESSIONAL SERVICES AGREEMENT
"maintenance" project, as defined by the Prevailing Wage Laws, and if the total compensation is $1,000 or more, Consultant agrees to fully comply with such Prevailing Wage Laws. City shall provide Consultant with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Consultant shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services available to interested parties upon request, and shall post copies at the Consultant's principal place of business and at the project site. It is the intent of the parties to effectuate the requirements of sections 1771, 1774, 1775, 1776, 1777.5, 1813, and 1815 of the Labor Code within this Agreement, and Consultant shall therefore comply with such Labor Code sections to the fullest extent required by law. Consultant shall defend, indemnify and hold the City, its officials, officers, employees, agents, and volunteers free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws.

3.4.2 Registration/DIR Compliance. If the Services are being performed on a public works project of over $25,000 when the project is for construction, alteration, demolition, installation, or repair work, or a public works project of over $15,000 when the project is for maintenance work, in addition to the foregoing, then pursuant to Labor Code sections 1725.5 and 1771.1, the Consultant and all subconsultants must be registered with the Department of Industrial Relations (“DIR”). Consultant shall maintain registration for the duration of the Project and require the same of any subconsultants.

3.4.3 Compliance Monitoring. This Project may also be subject to compliance monitoring and enforcement by the DIR. It shall be Consultant’s sole responsibility to comply with all applicable registration and labor compliance requirements, including the submission of payroll records directly to the DIR. Any stop orders issued by the DIR against Consultant or any subconsultant that affect Consultant’s performance of services, including any delay, shall be Consultant’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Consultant caused delay and shall not be compensable by the City. Consultant shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the DIR against Consultant or any subconsultant.

3.4.4 Labor Certification. By its signature hereunder, Consultant certifies that it is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker's Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services.

3.5 Termination of Agreement.

3.5.1.1 Grounds for Termination. City may, by written notice to Consultant, terminate the whole or any part of this Agreement at any time and without cause by giving written notice to Consultant of such termination, and specifying the effective date thereof, at least seven (7) days before the effective date of such termination. Upon termination, Consultant shall be compensated only for those Services which have been adequately rendered to City, and Consultant shall be entitled to no further compensation. Consultant may not terminate this Agreement except for cause. The rights and remedies of the City provided in this section shall not be exclusive and are in addition to any other rights and remedies provided by law, equity or under this Agreement.
741
46700.00100\40935195.1
BB&K (2023) -11- PROFESSIONAL SERVICES AGREEMENT

3.5.1.2 Effect of Termination. If this Agreement is terminated as provided herein, City may require Consultant to provide all finished or unfinished Documents and Data and other information of any kind prepared by Consultant in connection with the performance of Services under this Agreement. Consultant shall be required to provide such document and other information within fifteen (15) days of the request.

3.5.1.3 Additional Services. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated.

3.6 Indemnification.

3.6.1 To the fullest extent permitted by law, Consultant shall defend (with counsel of City’s choosing), indemnify and hold the City, its officials, officers, employees, volunteers, and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Consultant, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Consultant’s Services, the Project or this Agreement, including without limitation the payment of all damages, expert witness fees and attorney’s fees and other related costs and expenses except such loss or damage caused by the sole negligence or willful misconduct of the City. Consultant's obligation to indemnify shall survive expiration or termination of this Agreement and shall not be restricted to insurance proceeds, if any, received by Consultant, the City, its officials, officers, employees, agents, or volunteers.

3.6.2 If Consultant’s obligation to defend, indemnify, and/or hold harmless arises out of Consultant’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Consultant’s indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Consultant, and, upon Consultant obtaining a final adjudication by a court of competent jurisdiction, Consultant’s liability for such claim, including the cost to defend, shall not exceed the Consultant’s proportionate percentage of fault.

3.7 General Provisions.

3.7.1 Accounting Records. Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to this Agreement. Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement.

3.7.2 Independent Contractors and Subcontracting.

3.7.2.1 Use of Consultants. Consultant is aware of statutory and case law regarding classification of workers as independent contractors, including California Labor Code Section 2750.3 and Dynamex Operations West, Inc. v. Superior Court, 4 Cal. 5th 903 742
46700.00100\40935195.1
BB&K (2023) -12- PROFESSIONAL SERVICES AGREEMENT
(2018). To ensure that Consultant is in compliance with the California Labor Code, Consultant shall only utilize its employees to provide the Services. Consultant may not provide the services through any independent contractor, subcontractor or subconsultant (“Subcontractor(s)”) unless approved by the City as set forth in Section 3.7.2.2 below. Consultant represents and warrants that all personnel who perform the Services on Consultant’s behalf are Consultant’s employees, and that Consultant complies with all applicable laws, rules and regulations governing its employees, including, but not limited to, the California Labor Code, Unemployment Insurance Code and all applicable Industrial Welfare Commission Wage Orders.

3.7.2.2 Prior Approval Required. Consultant shall not use any Subcontractor to provide the Services, or any portion of the work required by this Agreement, without prior written approval of City. In the event that City authorizes Consultant to use a Subcontractor, Consultant shall enter into a written agreement with the Subcontractor, which must include all provisions of the Agreement, including a restriction on the Subcontractor’s use of further independent contractors, subcontractors or subconsultants without the City’s prior written consent.

3.7.3 Delivery of Notices. All notices permitted or required under this Agreement shall be given to the respective parties at the following address, or at such other address as the respective parties may provide in writing for this purpose:

Consultant: 22nd Century Technologies, Inc.
1 Executive Drive, Suite 285
Somerset, NJ 08873
ATTN: Isha Sharma, Contract Manager
City: City of Ontario
303 East “B” Street
Ontario, CA 91764
ATTN: Angela Lopez, Executive Director Human
Resources/Risk Management
Such notice shall be deemed made when personally delivered or when mailed, forty-eight (48) hours after deposit in the U.S. Mail, first class postage prepaid and addressed to the party at its applicable address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.

3.7.4 Ownership of Materials and Confidentiality.

3.7.4.1 Documents & Data; Licensing of Intellectual Property. This Agreement creates a non-exclusive and perpetual license for City to copy, use, modify, reuse, or sublicense any and all copyrights, designs, and other intellectual property embodied in plans, specifications, studies, drawings, estimates, and other documents or works of authorship fixed in any tangible medium of expression, including but not limited to, physical drawings or data magnetically or otherwise recorded on computer diskettes, which are prepared or caused to be prepared by Consultant under this Agreement ("Documents & Data"). All Documents & Data shall be and remain the property of City, and shall not be used in whole or in substantial part by Consultant on other projects without the City’s express written permission. Within thirty (30) days following the completion, suspension, abandonment or termination of this Agreement, Consultant shall provide to City reproducible copies of all Documents & Data, in a form and amount required 743
46700.00100\40935195.1
BB&K (2023) -13- PROFESSIONAL SERVICES AGREEMENT
by City. City reserves the right to select the method of document reproduction and to establish where the reproduction will be accomplished. The reproduction expense shall be borne by City at the actual cost of duplication. In the event of a dispute regarding the amount of compensation to which the Consultant is entitled under the termination provisions of this Agreement, Consultant shall provide all Documents & Data to City upon payment of the undisputed amount. Consultant shall have no right to retain or fail to provide to City any such documents pending resolution of the dispute. In addition, Consultant shall retain copies of all Documents & Data on file for a minimum of fifteen (15) years following completion of the Project, and shall make copies available to City upon the payment of actual reasonable duplication costs. Before destroying the Documents & Data following this retention period, Consultant shall make a reasonable effort to notify City and provide City with the opportunity to obtain the documents.

3.7.4.2 Subconsultants. Consultant shall require all subconsultants to agree in writing that City is granted a non-exclusive and perpetual license for any Documents & Data the subconsultant prepares under this Agreement. Consultant represents and warrants that Consultant has the legal right to license any and all Documents & Data. Consultant makes no such representation and warranty in regard to Documents & Data which were prepared by design professionals other than Consultant or its subconsultants, or those provided to Consultant by the City.

3.7.4.3 Right to Use. City shall not be limited in any way in its use or reuse of the Documents and Data or any part of them at any time for purposes of this Project or another project, provided that any such use not within the purposes intended by this Agreement or on a project other than this Project without employing the services of Consultant shall be at City’s sole risk. If City uses or reuses the Documents & Data on any project other than this Project, it shall remove the Consultant’s seal from the Documents & Data and indemnify and hold harmless Consultant and its officers, directors, agents and employees from claims arising out of the negligent use or re-use of the Documents & Data on such other project. Consultant shall be responsible and liable for its Documents & Data, pursuant to the terms of this Agreement, only with respect to the condition of the Documents & Data at the time they are provided to the City upon completion, suspension, abandonment or termination. Consultant shall not be responsible or liable for any revisions to the Documents & Data made by any party other than Consultant, a party for whom the Consultant is legally responsible or liable, or anyone approved by the Consultant.

3.7.4.4 Indemnification. Consultant shall defend, indemnify and hold the City, its directors, officials, officers, employees, volunteers and agents free and harmless, pursuant to the indemnification provisions of this Agreement, for any alleged infringement of any patent, copyright, trade secret, trade name, trademark, or any other proprietary right of any person or entity in consequence of the use on the Project by City of the Documents & Data, including any method, process, product, or concept specified or depicted.

3.7.4.5 Confidentiality. All ideas, memoranda, specifications, plans, procedures, drawings, descriptions, computer program data, input record data, written information, and other Documents & Data either created by or provided to Consultant in connection with the performance of this Agreement shall be held confidential by Consultant. Such materials shall not, without the prior written consent of City, be used by Consultant for any purposes other than the performance of the Services. Nor shall such materials be disclosed to any person or entity not connected with the performance of the Services or the Project. Nothing furnished to Consultant which is otherwise known to Consultant or is generally known, or has 744
46700.00100\40935195.1
BB&K (2023) -14- PROFESSIONAL SERVICES AGREEMENT
become known, to the related industry shall be deemed confidential. Consultant shall not use City's name or insignia, photographs of the Project, or any publicity pertaining to the Services or the Project in any magazine, trade paper, newspaper, television or radio production or other similar medium without the prior written consent of City.

3.7.4.6 Confidential Information. The City shall refrain from releasing Consultant’s proprietary information ("Proprietary Information") unless the City's legal counsel determines that the release of the Proprietary Information is required by the California Public Records Act or other applicable state or federal law, or order of a court of competent jurisdiction, in which case the City shall notify Consultant of its intention to release Proprietary Information.

Consultant shall have five (5) working days after receipt of the release notice to give City written notice of Consultant's objection to the City's release of Proprietary Information. Consultant shall indemnify, defend and hold harmless the City, and its officers, directors, employees, and agents from and against all liability, loss, cost or expense (including attorney’s fees) arising out of a legal action brought to compel the release of Proprietary Information. City shall not release the Proprietary Information after receipt of an objection notice unless either: (1) Consultant fails to fully indemnify, defend (with City's choice of legal counsel), and hold City harmless from any legal action brought to compel such release; and/or (2) a final and non-appealable order by a court of competent jurisdiction requires that City release such information.

3.7.5 Cooperation; Further Acts. The Parties shall fully cooperate with one another, and shall take any additional acts or sign any additional documents as may be necessary, appropriate or convenient to attain the purposes of this Agreement.

3.7.6 Entire Agreement. This Agreement contains the entire agreement of the Parties with respect to the subject matter hereof, and supersedes all prior negotiations, understandings or agreements.

3.7.7 Attorneys’ Fees. If either party commences an action against the other party, either legal, administrative or otherwise, arising out of or in connection with this Agreement, the prevailing party in such litigation shall be entitled to have and recover from the losing party reasonable attorneys’ fees and all costs of such action.

3.7.8 Governing Law. This Agreement shall be governed by the laws of the State of California. Venue shall be in San Bernardino County. In addition to any and all contract requirements pertaining to notices of and requests for compensation or payment for extra work, disputed work, claims and/or changed conditions, Consultant must comply with the claim procedures set forth in Government Code sections 900 et seq. prior to filing any lawsuit against the City. Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to extra work, disputed work, claims, and/or changed conditions have been followed by Consultant. If no such Government Code claim is submitted, or if any prerequisite contractual requirements are not otherwise satisfied as specified herein, Consultant shall be barred from bringing and maintaining a valid lawsuit against the City.

3.7.9 Time of Essence. Time is of the essence for each and every provision of this Agreement.

3.7.10 City's Right to Employ Other Consultants. City reserves right to employ other consultants in connection with this Project.
745
46700.00100\40935195.1
BB&K (2023) -15- PROFESSIONAL SERVICES AGREEMENT

3.7.11 Successors and Assigns. This Agreement shall be binding on the successors and assigns of the parties.

3.7.12 Assignment or Transfer. Consultant shall not assign, sublet, or transfer this Agreement or any rights under or interest in this Agreement without the written consent of the City, which may be withheld for any reason. Any attempt to so assign or so transfer without such consent shall be void and without legal effect and shall constitute grounds for termination.

Consultant shall not subcontract any portion of the Services required by this Agreement, except as expressly stated herein, without prior written approval of City. Subcontracts, if any, shall contain a provision making them subject to all provisions stipulated in this Agreement.

3.7.13 Construction; References; Captions. Since the Parties or their agents have participated fully in the preparation of this Agreement, the language of this Agreement shall be construed simply, according to its fair meaning, and not strictly for or against any Party. Any term referencing time, days or period for performance shall be deemed calendar days and not work days. All references to Consultant include all personnel, employees, agents, and subconsultants of Consultant, except as otherwise specified in this Agreement. All references to City include its elected officials, officers, employees, agents, and volunteers except as otherwise specified in this Agreement. The captions of the various articles and paragraphs are for convenience and ease of reference only, and do not define, limit, augment, or describe the scope, content, or intent of this Agreement.

3.7.14 Amendment; Modification. No supplement, modification, or amendment of this Agreement shall be binding unless executed in writing and signed by both Parties.

3.7.15 Waiver. No waiver of any default shall constitute a waiver of any other default or breach, whether of the same or other covenant or condition. No waiver, benefit, privilege, or service voluntarily given or performed by a Party shall give the other Party any contractual rights by custom, estoppel, or otherwise.

3.7.16 No Third-Party Beneficiaries. There are no intended third party beneficiaries of any right or obligation assumed by the Parties.

3.7.17 Invalidity; Severability. If any portion of this Agreement is declared invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect.

3.7.18 Prohibited Interests. Consultant maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Consultant, to solicit or secure this Agreement. Consultant warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. Consultant further agrees to file, or shall cause its employees or subconsultants to file, a Statement of Economic Interest with the City’s Filing Officer as required under state law in the performance of the Services. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability. For the term of this Agreement, no member, officer or employee of City, during the term of his or her service with City, shall have any direct interest in this Agreement, or obtain any present or anticipated material benefit arising therefrom. 746
46700.00100\40935195.1
BB&K (2023) -16- PROFESSIONAL SERVICES AGREEMENT

3.7.19 Authority to Enter Agreement. Consultant has all requisite power and authority to conduct its business and to execute, deliver, and perform the Agreement. Each Party warrants that the individuals who have signed this Agreement have the legal power, right, and authority to make this Agreement and bind each respective Party.

3.7.20 Counterparts. This Agreement may be signed in counterparts, each of which shall constitute an original.

3.7.21 Survival. All rights and obligations hereunder that by their nature are to continue after any expiration or termination of this Agreement, including, but not limited to, the indemnification obligations, shall survive any such expiration or termination.

SIGNATURES ON NEXT PAGE
747
46700.00100\40935195.1
BB&K (2023) -17- PROFESSIONAL SERVICES AGREEMENT

SIGNATURE PAGE TO PROFESSIONAL SERVICES AGREEMENT

BETWEEN THE CITY OF ONTARIO AND
22nd Century Technologies, Inc.

IN WITNESS WHEREOF, each of the Parties has caused this Agreement to be executed on the day and year first above written.

CITY OF ONTARIO 22nd Century Technologies, Inc.

By: AAA
Its: BBB
Printed Name: CCC
By: DDD
Its: EEE
Printed Name: FFF
[If Corporation, TWO SIGNATURES,
President OR Vice President AND Secretary
OR Treasurer REQUIRED]
Approved By:

Scott Ochoa
City Manager
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:

City Clerk
748
46700.00100\40935195.1
BB&K (2023) Exhibit “A”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "A"

SCOPE OF SERVICES

PROPOSED SCOPE OF SERVICES
749
46700.00100
\40935195.1
BB&K (2023) Exhibit “A-I-1” PROFESSIONAL SERVICES AGREEMENT 750
46700.00100\40935195.1
BB&K (2023) Exhibit “B”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "B"

SCHEDULE OF SERVICES
751
46700.00100\40935195.1
BB&K (2023) Exhibit “C”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "C"

COMPENSATION
752
46700.00100\40935195.1
BB&K (2023) Exhibit “C”-1 PROFESSIONAL SERVICES AGREEMENT

CITY OF ONTARIO

PROFESSIONAL SERVICES AGREEMENT

1. PARTIES AND DATE.

This Agreement is made and entered as of ____________, by and between the City of Ontario, a municipal corporation organized under the laws of the State of California with its principal place of business at 303 East “B” Street, Ontario, California 91764-4196, County of San Bernardino, State of California ("City") and Staffing Network, LLC, a Corporation, with its principal place of business at 1815 S. Meyers Road, Suite 600, Oakbrook, IL 60181 (“Consultant”). City and Consultant are sometimes individually referred to herein as "Party" and collectively as "Parties."

2. RECITALS.

2.1 Consultant.

Consultant desires to perform and assume responsibility for the provision of certain professional services required by the City on the terms and conditions set forth in this Agreement.

Consultant represents that it is experienced in providing temporary staffing services to public clients, is licensed in the State of California, and is familiar with the plans of City.

2.2 Project.

City desires to engage Consultant to render such professional services for temporary staffing services for the City on an as-needed basis (“Project”) as set forth in this Agreement.

3. TERMS.

3.1 Scope of Services and Term.

3.1.1 General Scope of Services. Consultant promises and agrees to furnish to the City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the professional temporary staffing consulting services necessary for the Project ("Services"). The Services are more particularly described in Exhibit "A" attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordance with, this Agreement, the exhibits attached hereto and incorporated herein by reference, and all applicable local, state and federal laws, rules and regulations.

PAUL S. LEON
MAYOR

DEBRA PORADA

MAYOR PRO TEM
ALAN D. WAPNER
JIM W. BOWMAN

RUBEN VALENCIA

COUNCIL MEMBERS

SHEILA MAUTZ

CITY CLERK
JAMES R. MILHISER

TREASURER

SCOTT OCHOA

CITY MANAGER
753
46700.00100\40935195.1
BB&K (2023) -2- PROFESSIONAL SERVICES AGREEMENT

3.1.2 Term. The term of this Agreement shall be from November 21, 2023 to November 21, 2026, unless earlier terminated as provided herein. The City shall have the unilateral option, at its sole discretion, to renew this Agreement automatically for no more than two (2) additional one-year terms, unless earlier terminated as provided herein. Consultant shall complete the Services within the term of this Agreement and shall meet any other established schedules and deadlines. The Parties may, by mutual, written consent, extend the term of this Agreement if necessary to complete the Services.

3.2 Compensation.

3.2.1 Compensation. Consultant shall receive compensation, including authorized reimbursements, for all Services rendered under this Agreement at the rates set forth in Exhibit "C" attached hereto and incorporated herein by reference. The total compensation shall not exceed One Million Three Hundred Thousand Dollars and Zero Cents ($1,300,000) without written approval of the City Council or City Manager, as applicable. Extra Work may be authorized, as described below, and if authorized, will be compensated at the rates and manner set forth in this Agreement.

3.2.2 Payment of Compensation. Consultant shall submit to City a monthly invoice which indicates work completed and hours of Services rendered by Consultant. The invoice shall describe the amount of Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the invoice.

City shall, within 30 days of receiving such invoice, review the invoice and pay all non-disputed and approved charges. If the City disputes any of Consultant's fees, the City shall give written notice to Consultant within thirty (30) days of receipt of an invoice of any disputed fees set forth therein. Payment shall not constitute acceptance of any Services completed by Consultant. The making of final payment shall not constitute a waiver of any claims by the City for any reason whatsoever.

3.2.3 Reimbursement for Expenses. Consultant shall not be reimbursed for any expenses unless authorized in writing by City, or included in Exhibit "C" of this Agreement.

3.2.4 Extra Work. At any time during the term of this Agreement, City may request that Consultant perform Extra Work. As used herein, "Extra Work" means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement.

Consultant shall not perform, nor be compensated for, Extra Work without written authorization from the City.

3.3 Responsibilities of Consultant.

3.3.1 Independent Contractor; Control and Payment of Subordinates. The Services shall be performed by Consultant or under its supervision. Consultant will determine the means, methods and details of performing the Services subject to the requirements of this Agreement. City retains Consultant on an independent contractor basis and not as an employee.

Any personnel performing the Services on behalf of Consultant shall not be employees of City and shall at all times be under Consultant's exclusive direction and control. Neither City, or any of its officials, officers, directors, employees or agents shall have control over the conduct of Consultant or any of Consultants officers, employees or agents, except as set forth in this Agreement. Consultant shall pay all wages, salaries, and other amounts due such personnel in 754
46700.00100\40935195.1
BB&K (2023) -3- PROFESSIONAL SERVICES AGREEMENT
connection with their performance of Services under this Agreement and as required by law.

Consultant shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers' compensation insurance.

3.3.2 Schedule of Services. Consultant shall perform the Services in a prompt and timely manner and in accordance with the Schedule of Services set forth in Exhibit "B" attached hereto and incorporated herein by reference. Consultant represents that it has the professional and technical personnel required to perform the Services expeditiously. Upon request of City, Consultant shall provide a more detailed schedule of anticipated performance to meet the Schedule of Services.

3.3.3 Conformance to Applicable Requirements. All work prepared by Consultant shall be subject to the approval of City.

3.3.4 Substitution of Key Personnel. Consultant has represented to City that certain key personnel will perform and coordinate the Services under this Agreement. Should one or more of such personnel become unavailable, Consultant may substitute other personnel of at least equal competence upon written approval of City. In the event that City and Consultant cannot agree as to the substitution of key personnel, City shall be entitled to terminate this Agreement for cause. The key personnel for performance of this Agreement are as follows:

Rebecca Coronel, Vice President of Operations.

3.3.5 City's Representative. The City hereby designates Angela Lopez, Executive Director Human Resources/Risk Management, or his/her designee, to act as its representative in all matters pertaining to the administration and performance of this Agreement ("City's Representative"). City's Representative shall have the power to act on behalf of the City for review and approval of all products submitted by Consultant but not the authority to enlarge the Scope of Services or change the total compensation due to Consultant under this Agreement.

The City Manager shall be authorized to act on City's behalf and to execute all necessary documents which enlarge the Scope of Services or change the Consultant's total compensation subject to the provisions contained in this Agreement. Consultant shall not accept direction or orders from any person other than the City Manager, City's Representative or his/her designee.

3.3.6 Consultant's Representative. Consultant hereby designates Rebecca Coronel, Vice President of Operations, or his/her designee, to act as its representative for the performance of this Agreement ("Consultant's Representative"). Consultant's Representative shall have full authority to represent and act on behalf of the Consultant for all purposes under this Agreement. The Consultant's Representative shall supervise and direct the Services, using his/her best skill and attention, and shall be responsible for all means, methods, techniques, sequences, and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.

3.3.7 Coordination of Services. Consultant agrees to work closely with City staff in the performance of Services and shall be available to City's staff, consultants and other staff at all reasonable times.

3.3.8 Standard of Care; Performance of Employees. Consultant shall perform all Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals in the same discipline in the State of 755
46700.00100\40935195.1
BB&K (2023) -4- PROFESSIONAL SERVICES AGREEMENT
California. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services. Consultant warrants that all employees and subconsultants shall have sufficient skill and experience to perform the Services assigned to them. Consultant represents that it, its employees and subconsultants have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services, and that such licenses and approvals shall be maintained throughout the term of this Agreement. Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant's failure to comply with the standard of care provided for herein. Any employee of the Consultant or its subconsultants who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed from the Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.

3.3.9 Period of Performance.

3.3.9.1 Consultant shall perform and complete all Services under this Agreement within the term set forth in Section 3.1.2 above (“Performance Time”). Consultant shall also perform the Services in strict accordance with any completion schedule or Project milestones described in Exhibits “A” or “B” attached hereto, or which may be separately agreed upon in writing by the City and Consultant (“Performance Milestones”). Consultant agrees that if the Services are not completed within the aforementioned Performance Time and/or pursuant to any such Performance Milestones developed pursuant to provisions of this Agreement, it is understood, acknowledged and agreed that the City will suffer damage.

3.3.9.2 Neither City nor Consultant shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the non-performing Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Consultant and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the services and Agreement.

3.3.9.3 Should a Force Majeure Event occur, the non-performing Party shall, within a reasonable time of being prevented from performing, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events and/or delays, regardless of the Party responsible for the delay, shall not entitle Consultant to any additional compensation.

Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement. 756
46700.00100\40935195.1
BB&K (2023) -5- PROFESSIONAL SERVICES AGREEMENT

3.3.10 Laws and Regulations; Employee/Labor Certification.

3.3.10.1 Compliance with Laws. Consultant shall keep itself fully informed of and in compliance with all local, state and federal laws, rules and regulations in any manner affecting the performance of the Project or the Services, including all Cal/OSHA requirements, and shall give all notices required by law. Consultant shall be liable for all violations of such laws and regulations in connection with the Services and this Agreement. All violations of such laws and regulations shall be grounds for the City to terminate the Agreement for cause.

3.3.10.2 Employment Eligibility; Consultant. Consultant certifies that it fully complies with all requirements and restrictions of state and federal law respecting the employment of undocumented aliens, including, but not limited to, the Immigration Reform and Control Act of 1986, as may be amended from time to time and shall require all subconsultants and sub-subconsultants to comply with the same. Consultant certifies that it has not committed a violation of any such law within the five (5) years immediately preceding the date of execution of this Agreement, and shall not violate any such law at any time during the term of the Agreement.

3.3.10.3 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subconsultant, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination. Consultant shall also comply with all relevant provisions of City's Minority Business Enterprise program, Affirmative Action Plan or other related programs or guidelines currently in effect or hereinafter enacted.

3.3.10.4 Air Quality. To the extent applicable, Consultant must fully comply with all applicable laws, rules and regulations in furnishing or using equipment and/or providing services, including, but not limited to, emissions limits and permitting requirements imposed by the South Coast Air Quality Management District (SCAQMD) and/or California Air Resources Board (CARB). Consultant shall indemnify City against any fines or penalties imposed by SCAQMD, CARB, or any other governmental or regulatory agency for violations of applicable laws, rules and/or regulations by Consultant, its subconsultants, or others for whom Consultant is responsible under its indemnity obligations provided for in this Agreement.

3.3.10.5 Water Quality Management and Compliance. Consultant shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Services including, without limitation, all applicable provisions of the City’s ordinances regulating water quality and storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251, et seq.); the California Porter-Cologne Water Quality Control Act (Water Code § 13000 et seq.); and any and all regulations, policies, or permits issued pursuant to any such authority. Consultant must additionally comply with the lawful requirements of the City, and any other municipality, drainage district, or other local agency with jurisdiction over the location where the Services are to be conducted, regulating water quality and storm water discharges. City may seek damages from Consultant for delay in completing the Services caused by Consultant’s failure to comply with the laws, regulations and policies described in this Section, or any other relevant water quality law, regulation, or policy.
757
46700.00100\40935195.1
BB&K (2023) -6- PROFESSIONAL SERVICES AGREEMENT

3.3.10.6 Safety. Consultant shall execute and maintain its work so as to avoid injury or damage to any person or property. In carrying out its Services, the Consultant shall at all times be in compliance with all applicable local, state and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of employees appropriate to the nature of the work and the conditions under which the work is to be performed.

3.3.11 Insurance.

3.3.11.1 Time for Compliance. Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurance required under this section. Failure to provide and maintain all required insurance shall be grounds for the City to terminate this Agreement for cause.

3.3.11.2 Types of Insurance Required. As a condition precedent to the effectiveness of this Agreement for work to be performed hereunder, and without limiting the indemnity provisions of the Agreement, the Consultant, in partial performance of its obligations under such Agreement, shall procure and maintain in full force and effect during the term of the Agreement the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Consultant agrees to amend, supplement or endorse the policies to do so.
(A) Commercial General Liability: Commercial General Liability Insurance which affords coverage at least as broad as Insurance Services Office "occurrence" form CG 00 01, or the exact equivalent, with limits of not less than $2,000,000 per occurrence and no less than $4,000,000 in the general aggregate. Defense costs shall be paid in addition to the limits. The policy shall contain no endorsements or provisions (1) limiting coverage for contractual liability; (2) excluding coverage for claims or suits by one insured against another (cross-liability); (3) products/completed operations liability; or (4) containing any other exclusion(s) contrary to the terms or purposes of this Agreement. (B) Automobile Liability Insurance: Automobile Liability Insurance with coverage at least as broad as Insurance Services Office Form CA 00 01 covering "Any Auto" (Symbol 1), or the exact equivalent, covering bodily injury and property damage for all activities with limits of not less than $2,000,000 combined limit for each occurrence. (C) Workers' Compensation: Workers' Compensation
Insurance, as required by the State of California and Employer's Liability Insurance with a limit of not less than $1,000,000 per accident for bodily injury and disease. (D) Professional Liability (Errors & Omissions): Professional Liability insurance or Errors & Omissions insurance appropriate to Consultant’s profession with limits of not less than $2,000,000. Covered professional services shall specifically include all work to be performed under the Agreement and delete any exclusions that may potentially affect the work to be performed (for example, any exclusions relating to lead, asbestos, pollution, testing, underground storage tanks, laboratory analysis, soil work, etc.). If coverage is written on a claims-made basis, the retroactive date shall precede the effective date of the initial Agreement and continuous coverage will be maintained or an extended reporting period will be exercised for a period of at least five (5) years from termination or expiration of this Agreement. 758
46700.00100\40935195.1
BB&K (2023) -7- PROFESSIONAL SERVICES AGREEMENT

3.3.11.3 Insurance Endorsements. Required insurance policies shall contain the following provisions, or Consultant shall provide endorsements on forms approved by the City to add the following provisions to the insurance policies:
(A) Commercial General Liability: (1) Additional Insured: The City, its officials, officers, employees, agents, and volunteers shall be additional insureds with regard to liability and defense of suits or claims arising out of the performance of the Agreement.

Additional Insured Endorsements shall not (1) be restricted to "ongoing operations"; (2) exclude "contractual liability"; (3) restrict coverage to "sole" liability of Consultant; or (4) contain any other exclusions contrary to the terms or purposes of this Agreement. For all policies of Commercial General Liability insurance, Consultant shall provide endorsements in the form of ISO CG 20 10 10 01 and 20 37 10 01 (or endorsements providing the exact same coverage) to effectuate this requirement. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (B) Automobile Liability: (1) Additional Insured: The City, its directors, officials, officers, employees, agents, and volunteers shall be covered as additional insureds with respect to the ownership, operation, maintenance, use, loading or unloading of any auto owned, leased, hired or borrowed by the Vendor or for which the Vendor is responsible. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium.
(C) Professional Liability (Errors & Omissions): 1) Cancellation:

Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) This insurance shall be written on a policy form coverage specifically designed to protect against acts, errors or omissions of the Consultant. “Covered Professional Services” as designated in the policy must specifically include work performed under this Agreement. The policy must “pay on behalf of” the insured and include a provision establishing the insurer’s duty to defend.
(D) Workers' Compensation: (1) Cancellation: Required
insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) Waiver of Subrogation: A waiver of subrogation stating that the insurer waives all rights of subrogation against the City, its officials, officers, employees, agents, and volunteers.

3.3.11.4 Primary and Non-Contributing Insurance. All policies of Commercial General Liability and Automobile Liability insurance shall be primary and any other insurance, deductible, or self-insurance maintained by the City, its officials, officers, employees, agents, or volunteers shall not contribute with this primary insurance. Policies shall contain or be endorsed to contain such provisions.

3.3.11.5 Waiver of Subrogation. All required insurance coverages, except for the professional liability coverage, shall contain or be endorsed to waiver of subrogation in favor of the City, its officials, officers, employees, agents, and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these specifications 759
46700.00100\40935195.1
BB&K (2023) -8- PROFESSIONAL SERVICES AGREEMENT
to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants.

3.3.11.6 Deductibles and Self-Insured Retentions. Any deductible or selfinsured retention must be approved in writing by the City and shall protect the City, its officials, officers, employees, agents, and volunteers in the same manner and to the same extent as they would have been protected had the policy or policies not contained a deductible or self-insured retention.

3.3.11.7 Evidence of Insurance. The Consultant, concurrently with the execution of the Agreement, and as a condition precedent to the effectiveness thereof, shall deliver either certified copies of the required policies, or original certificates on forms approved by the City, together with all endorsements affecting each policy. Required insurance policies shall not be in compliance if they include any limiting provision or endorsement that has not been submitted to the City for approval. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf. At least fifteen (15 days) prior to the expiration of any such policy, evidence of insurance showing that such insurance coverage has been renewed or extended shall be filed with the City. If such coverage is cancelled or reduced and not replaced immediately so as to avoid a lapse in the required coverage, Consultant shall, within ten (10) days after receipt of written notice of such cancellation or reduction of coverage, file with the City evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies.

3.3.11.8 Acceptability of Insurers. Each such policy shall be from a company or companies with a current A.M. Best's rating of no less than A:VII and authorized to transact business of insurance in the State of California, or otherwise allowed to place insurance through surplus line brokers under applicable provisions of the California Insurance Code or any federal law.

3.3.11.9 Enforcement of Agreement Provisions (non estoppel).

Consultant acknowledges and agrees that actual or alleged failure on the part of the City to inform Consultant of non-compliance with any requirement imposes no additional obligation on the City nor does it waive any rights hereunder.

3.3.11.10 Requirements Not Limiting. Requirement of specific coverage or minimum limits contained in this Section are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance.

3.3.11.11 Additional Insurance Provisions
(A) The foregoing requirements as to the types and limits of insurance coverage to be maintained by Consultant, and any approval of said insurance by the City, is not intended to and shall not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Consultant pursuant to this Agreement, including but not limited to, the provisions concerning indemnification.
(B) If at any time during the life of the Agreement, any policy of insurance required under this Agreement does not comply with these specifications or is canceled 760
46700.00100\40935195.1
BB&K (2023) -9- PROFESSIONAL SERVICES AGREEMENT
and not replaced, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Consultant or City will withhold amounts sufficient to pay premium from Consultant payments. In the alternative, City may cancel this Agreement.
(C) The City may require the Consultant to provide complete copies of all insurance policies in effect for the duration of the Project. (D) Neither the City nor any of its officials, officers, employees, agents or volunteers shall be personally responsible for any liability arising under or by virtue of this Agreement.
(E) The limits set forth herein shall apply separately to each insured against whom claims are made or suits are brought, except with respect to the limits of liability. Further the limits set forth herein shall not be construed to relieve the Consultant from liability in excess of such coverage, nor shall it limit the Consultant’s indemnification obligations to the City and shall not preclude the City from taking such other actions available to the City under other provisions of the Agreement or law.
(F) Consultant shall report to the City, in addition to Consultant’s insurer, any and all insurance claims submitted by Consultant in connection with the Services under this Agreement.

3.3.11.12 Insurance for Subconsultants. Consultant shall include all subconsultants engaged in any work for Consultant relating to this Agreement as additional insureds under the Consultant's policies, or the Consultant shall be responsible for causing subconsultants to purchase the appropriate insurance in compliance with the terms of these Insurance Requirements, including adding the City, its officials, officers, employees, agents, and volunteers as additional insureds to the subconsultant's policies. All policies of Commercial General Liability insurance provided by Consultant’s subconsultants performing work relating to this Agreement shall be endorsed to name the City, its officials, officers, employees, agents and volunteers as additional insureds using endorsement form ISO CG 20 38 04 13 or an endorsement providing equivalent coverage. Consultant shall not allow any subconsultant to commence work on any subcontract relating to this Agreement until it has received satisfactory evidence of subconsultant’s compliance with all insurance requirements under this Agreement, to the extent applicable. The Consultant shall provide satisfactory evidence of compliance with this section upon request of the City.

3.4 Labor Code Requirements.

3.4.1 Prevailing Wages. Consultant is aware of the requirements of California Labor Code Section 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., ("Prevailing Wage Laws"), which require the payment of prevailing wage rates and the performance of other requirements on "public works" and "maintenance" projects. If the Services are being performed as part of an applicable "public works" or "maintenance" project, as defined by the Prevailing Wage Laws, and if the total compensation is $1,000 or more, Consultant agrees to fully comply with such Prevailing Wage Laws. City shall provide Consultant with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Consultant shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services 761
46700.00100\40935195.1
BB&K (2023) -10- PROFESSIONAL SERVICES AGREEMENT
available to interested parties upon request, and shall post copies at the Consultant's principal place of business and at the project site. It is the intent of the parties to effectuate the requirements of sections 1771, 1774, 1775, 1776, 1777.5, 1813, and 1815 of the Labor Code within this Agreement, and Consultant shall therefore comply with such Labor Code sections to the fullest extent required by law. Consultant shall defend, indemnify and hold the City, its officials, officers, employees, agents, and volunteers free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws.

3.4.2 Registration/DIR Compliance. If the Services are being performed on a public works project of over $25,000 when the project is for construction, alteration, demolition, installation, or repair work, or a public works project of over $15,000 when the project is for maintenance work, in addition to the foregoing, then pursuant to Labor Code sections 1725.5 and 1771.1, the Consultant and all subconsultants must be registered with the Department of Industrial Relations (“DIR”). Consultant shall maintain registration for the duration of the Project and require the same of any subconsultants.

3.4.3 Compliance Monitoring. This Project may also be subject to compliance monitoring and enforcement by the DIR. It shall be Consultant’s sole responsibility to comply with all applicable registration and labor compliance requirements, including the submission of payroll records directly to the DIR. Any stop orders issued by the DIR against Consultant or any subconsultant that affect Consultant’s performance of services, including any delay, shall be Consultant’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Consultant caused delay and shall not be compensable by the City. Consultant shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the DIR against Consultant or any subconsultant.

3.4.4 Labor Certification. By its signature hereunder, Consultant certifies that it is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker's Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services.

3.5 Termination of Agreement.

3.5.1.1 Grounds for Termination. City may, by written notice to Consultant, terminate the whole or any part of this Agreement at any time and without cause by giving written notice to Consultant of such termination, and specifying the effective date thereof, at least seven (7) days before the effective date of such termination. Upon termination, Consultant shall be compensated only for those Services which have been adequately rendered to City, and Consultant shall be entitled to no further compensation. Consultant may not terminate this Agreement except for cause. The rights and remedies of the City provided in this section shall not be exclusive and are in addition to any other rights and remedies provided by law, equity or under this Agreement.

3.5.1.2 Effect of Termination. If this Agreement is terminated as provided herein, City may require Consultant to provide all finished or unfinished Documents and Data and other information of any kind prepared by Consultant in connection with the performance of Services under this Agreement. Consultant shall be required to provide such document and other information within fifteen (15) days of the request. 762
46700.00100\40935195.1
BB&K (2023) -11- PROFESSIONAL SERVICES AGREEMENT

3.5.1.3 Additional Services. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated.

3.6 Indemnification.

3.6.1 To the fullest extent permitted by law, Consultant shall defend (with counsel of City’s choosing), indemnify and hold the City, its officials, officers, employees, volunteers, and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Consultant, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Consultant’s Services, the Project or this Agreement, including without limitation the payment of all damages, expert witness fees and attorney’s fees and other related costs and expenses except such loss or damage caused by the sole negligence or willful misconduct of the City. Consultant's obligation to indemnify shall survive expiration or termination of this Agreement and shall not be restricted to insurance proceeds, if any, received by Consultant, the City, its officials, officers, employees, agents, or volunteers.

3.6.2 If Consultant’s obligation to defend, indemnify, and/or hold harmless arises out of Consultant’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Consultant’s indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Consultant, and, upon Consultant obtaining a final adjudication by a court of competent jurisdiction, Consultant’s liability for such claim, including the cost to defend, shall not exceed the Consultant’s proportionate percentage of fault.

3.7 General Provisions.

3.7.1 Accounting Records. Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to this Agreement. Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement.

3.7.2 Independent Contractors and Subcontracting.

3.7.2.1 Use of Consultants. Consultant is aware of statutory and case law regarding classification of workers as independent contractors, including California Labor Code Section 2750.3 and Dynamex Operations West, Inc. v. Superior Court, 4 Cal. 5th 903 (2018). To ensure that Consultant is in compliance with the California Labor Code, Consultant shall only utilize its employees to provide the Services. Consultant may not provide the services through any independent contractor, subcontractor or subconsultant (“Subcontractor(s)”) unless approved by the City as set forth in Section 3.7.2.2 below. Consultant represents and warrants that all personnel who perform the Services on Consultant’s behalf are Consultant’s employees, and that Consultant complies with all applicable laws, rules and regulations governing its 763
46700.00100\40935195.1
BB&K (2023) -12- PROFESSIONAL SERVICES AGREEMENT
employees, including, but not limited to, the California Labor Code, Unemployment Insurance Code and all applicable Industrial Welfare Commission Wage Orders.

3.7.2.2 Prior Approval Required. Consultant shall not use any Subcontractor to provide the Services, or any portion of the work required by this Agreement, without prior written approval of City. In the event that City authorizes Consultant to use a Subcontractor, Consultant shall enter into a written agreement with the Subcontractor, which must include all provisions of the Agreement, including a restriction on the Subcontractor’s use of further independent contractors, subcontractors or subconsultants without the City’s prior written consent.

3.7.3 Delivery of Notices. All notices permitted or required under this Agreement shall be given to the respective parties at the following address, or at such other address as the respective parties may provide in writing for this purpose:

Consultant: Staffing Network, LLC
1815 S. Meyers Place, Suite 600
Oakbrook, IL 60181
ATTN: Rebecca Coronel, Vice President of Operations
City: City of Ontario
303 East “B” Street
Ontario, CA 91764
ATTN: Angela Lopez, Executive Director Human
Resources/Risk Management
Such notice shall be deemed made when personally delivered or when mailed, forty-eight (48) hours after deposit in the U.S. Mail, first class postage prepaid and addressed to the party at its applicable address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.

3.7.4 Ownership of Materials and Confidentiality.

3.7.4.1 Documents & Data; Licensing of Intellectual Property. This Agreement creates a non-exclusive and perpetual license for City to copy, use, modify, reuse, or sublicense any and all copyrights, designs, and other intellectual property embodied in plans, specifications, studies, drawings, estimates, and other documents or works of authorship fixed in any tangible medium of expression, including but not limited to, physical drawings or data magnetically or otherwise recorded on computer diskettes, which are prepared or caused to be prepared by Consultant under this Agreement ("Documents & Data"). All Documents & Data shall be and remain the property of City, and shall not be used in whole or in substantial part by Consultant on other projects without the City’s express written permission. Within thirty (30) days following the completion, suspension, abandonment or termination of this Agreement, Consultant shall provide to City reproducible copies of all Documents & Data, in a form and amount required by City. City reserves the right to select the method of document reproduction and to establish where the reproduction will be accomplished. The reproduction expense shall be borne by City at the actual cost of duplication. In the event of a dispute regarding the amount of compensation to which the Consultant is entitled under the termination provisions of this Agreement, Consultant shall provide all Documents & Data to City upon payment of the undisputed amount. Consultant shall have no right to retain or fail to provide to City any such documents pending resolution of 764
46700.00100\40935195.1
BB&K (2023) -13- PROFESSIONAL SERVICES AGREEMENT
the dispute. In addition, Consultant shall retain copies of all Documents & Data on file for a minimum of fifteen (15) years following completion of the Project, and shall make copies available to City upon the payment of actual reasonable duplication costs. Before destroying the Documents & Data following this retention period, Consultant shall make a reasonable effort to notify City and provide City with the opportunity to obtain the documents.

3.7.4.2 Subconsultants. Consultant shall require all subconsultants to agree in writing that City is granted a non-exclusive and perpetual license for any Documents & Data the subconsultant prepares under this Agreement. Consultant represents and warrants that Consultant has the legal right to license any and all Documents & Data. Consultant makes no such representation and warranty in regard to Documents & Data which were prepared by design professionals other than Consultant or its subconsultants, or those provided to Consultant by the City.

3.7.4.3 Right to Use. City shall not be limited in any way in its use or reuse of the Documents and Data or any part of them at any time for purposes of this Project or another project, provided that any such use not within the purposes intended by this Agreement or on a project other than this Project without employing the services of Consultant shall be at City’s sole risk. If City uses or reuses the Documents & Data on any project other than this Project, it shall remove the Consultant’s seal from the Documents & Data and indemnify and hold harmless Consultant and its officers, directors, agents and employees from claims arising out of the negligent use or re-use of the Documents & Data on such other project. Consultant shall be responsible and liable for its Documents & Data, pursuant to the terms of this Agreement, only with respect to the condition of the Documents & Data at the time they are provided to the City upon completion, suspension, abandonment or termination. Consultant shall not be responsible or liable for any revisions to the Documents & Data made by any party other than Consultant, a party for whom the Consultant is legally responsible or liable, or anyone approved by the Consultant.

3.7.4.4 Indemnification. Consultant shall defend, indemnify and hold the City, its directors, officials, officers, employees, volunteers and agents free and harmless, pursuant to the indemnification provisions of this Agreement, for any alleged infringement of any patent, copyright, trade secret, trade name, trademark, or any other proprietary right of any person or entity in consequence of the use on the Project by City of the Documents & Data, including any method, process, product, or concept specified or depicted.

3.7.4.5 Confidentiality. All ideas, memoranda, specifications, plans, procedures, drawings, descriptions, computer program data, input record data, written information, and other Documents & Data either created by or provided to Consultant in connection with the performance of this Agreement shall be held confidential by Consultant. Such materials shall not, without the prior written consent of City, be used by Consultant for any purposes other than the performance of the Services. Nor shall such materials be disclosed to any person or entity not connected with the performance of the Services or the Project. Nothing furnished to Consultant which is otherwise known to Consultant or is generally known, or has become known, to the related industry shall be deemed confidential. Consultant shall not use City's name or insignia, photographs of the Project, or any publicity pertaining to the Services or the Project in any magazine, trade paper, newspaper, television or radio production or other similar medium without the prior written consent of City. 765
46700.00100\40935195.1
BB&K (2023) -14- PROFESSIONAL SERVICES AGREEMENT

3.7.4.6 Confidential Information. The City shall refrain from releasing Consultant’s proprietary information ("Proprietary Information") unless the City's legal counsel determines that the release of the Proprietary Information is required by the California Public Records Act or other applicable state or federal law, or order of a court of competent jurisdiction, in which case the City shall notify Consultant of its intention to release Proprietary Information.

Consultant shall have five (5) working days after receipt of the release notice to give City written notice of Consultant's objection to the City's release of Proprietary Information. Consultant shall indemnify, defend and hold harmless the City, and its officers, directors, employees, and agents from and against all liability, loss, cost or expense (including attorney’s fees) arising out of a legal action brought to compel the release of Proprietary Information. City shall not release the Proprietary Information after receipt of an objection notice unless either: (1) Consultant fails to fully indemnify, defend (with City's choice of legal counsel), and hold City harmless from any legal action brought to compel such release; and/or (2) a final and non-appealable order by a court of competent jurisdiction requires that City release such information.

3.7.5 Cooperation; Further Acts. The Parties shall fully cooperate with one another, and shall take any additional acts or sign any additional documents as may be necessary, appropriate or convenient to attain the purposes of this Agreement.

3.7.6 Entire Agreement. This Agreement contains the entire agreement of the Parties with respect to the subject matter hereof, and supersedes all prior negotiations, understandings or agreements.

3.7.7 Attorneys’ Fees. If either party commences an action against the other party, either legal, administrative or otherwise, arising out of or in connection with this Agreement, the prevailing party in such litigation shall be entitled to have and recover from the losing party reasonable attorneys’ fees and all costs of such action.

3.7.8 Governing Law. This Agreement shall be governed by the laws of the State of California. Venue shall be in San Bernardino County. In addition to any and all contract requirements pertaining to notices of and requests for compensation or payment for extra work, disputed work, claims and/or changed conditions, Consultant must comply with the claim procedures set forth in Government Code sections 900 et seq. prior to filing any lawsuit against the City. Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to extra work, disputed work, claims, and/or changed conditions have been followed by Consultant. If no such Government Code claim is submitted, or if any prerequisite contractual requirements are not otherwise satisfied as specified herein, Consultant shall be barred from bringing and maintaining a valid lawsuit against the City.

3.7.9 Time of Essence. Time is of the essence for each and every provision of this Agreement.

3.7.10 City's Right to Employ Other Consultants. City reserves right to employ other consultants in connection with this Project.

3.7.11 Successors and Assigns. This Agreement shall be binding on the successors and assigns of the parties.

3.7.12 Assignment or Transfer. Consultant shall not assign, sublet, or transfer this 766
46700.00100\40935195.1
BB&K (2023) -15- PROFESSIONAL SERVICES AGREEMENT
Agreement or any rights under or interest in this Agreement without the written consent of the City, which may be withheld for any reason. Any attempt to so assign or so transfer without such consent shall be void and without legal effect and shall constitute grounds for termination.

Consultant shall not subcontract any portion of the Services required by this Agreement, except as expressly stated herein, without prior written approval of City. Subcontracts, if any, shall contain a provision making them subject to all provisions stipulated in this Agreement.

3.7.13 Construction; References; Captions. Since the Parties or their agents have participated fully in the preparation of this Agreement, the language of this Agreement shall be construed simply, according to its fair meaning, and not strictly for or against any Party. Any term referencing time, days or period for performance shall be deemed calendar days and not work days. All references to Consultant include all personnel, employees, agents, and subconsultants of Consultant, except as otherwise specified in this Agreement. All references to City include its elected officials, officers, employees, agents, and volunteers except as otherwise specified in this Agreement. The captions of the various articles and paragraphs are for convenience and ease of reference only, and do not define, limit, augment, or describe the scope, content, or intent of this Agreement.

3.7.14 Amendment; Modification. No supplement, modification, or amendment of this Agreement shall be binding unless executed in writing and signed by both Parties.

3.7.15 Waiver. No waiver of any default shall constitute a waiver of any other default or breach, whether of the same or other covenant or condition. No waiver, benefit, privilege, or service voluntarily given or performed by a Party shall give the other Party any contractual rights by custom, estoppel, or otherwise.

3.7.16 No Third-Party Beneficiaries. There are no intended third party beneficiaries of any right or obligation assumed by the Parties.

3.7.17 Invalidity; Severability. If any portion of this Agreement is declared invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect.

3.7.18 Prohibited Interests. Consultant maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Consultant, to solicit or secure this Agreement. Consultant warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. Consultant further agrees to file, or shall cause its employees or subconsultants to file, a Statement of Economic Interest with the City’s Filing Officer as required under state law in the performance of the Services. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability. For the term of this Agreement, no member, officer or employee of City, during the term of his or her service with City, shall have any direct interest in this Agreement, or obtain any present or anticipated material benefit arising therefrom.

3.7.19 Authority to Enter Agreement. Consultant has all requisite power and authority to conduct its business and to execute, deliver, and perform the Agreement. Each Party warrants that the individuals who have signed this Agreement have the legal power, right, and authority to make this Agreement and bind each respective Party. 767
46700.00100\40935195.1
BB&K (2023) -16- PROFESSIONAL SERVICES AGREEMENT

3.7.20 Counterparts. This Agreement may be signed in counterparts, each of which shall constitute an original.

3.7.21 Survival. All rights and obligations hereunder that by their nature are to continue after any expiration or termination of this Agreement, including, but not limited to, the indemnification obligations, shall survive any such expiration or termination.

SIGNATURES ON NEXT PAGE
768
46700.00100\40935195.1
BB&K (2023) -17- PROFESSIONAL SERVICES AGREEMENT

SIGNATURE PAGE TO PROFESSIONAL SERVICES AGREEMENT

BETWEEN THE CITY OF ONTARIO AND
Staffing Network, LLC
IN WITNESS WHEREOF, each of the Parties has caused this Agreement to be executed on the day and year first above written.

CITY OF ONTARIO Staffing Network, LLC
By: AAA
Its: BBB
Printed Name: CCC
By: DDD
Its: EEE
Printed Name: FFF
[If Corporation, TWO SIGNATURES,
President OR Vice President AND Secretary
OR Treasurer REQUIRED]
Approved By:

Scott Ochoa
City Manager
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:

City Clerk
769
46700.00100\40935195.1
BB&K (2023) Exhibit “A”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "A"

SCOPE OF SERVICES

PROPOSED SCOPE OF SERVICES
770
46700.00100\40935195.1
BB&K (2023) Exhibit “B”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "B"

SCHEDULE OF SERVICES
771
46700.00100\40935195.1
BB&K (2023) Exhibit “C”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "C"

COMPENSATION
772
46700.00100\40935195.1
BB&K (2023) Exhibit “C”-1 PROFESSIONAL SERVICES AGREEMENT

CITY OF ONTARIO

PROFESSIONAL SERVICES AGREEMENT

1. PARTIES AND DATE.

This Agreement is made and entered as of ____________, by and between the City of Ontario, a municipal corporation organized under the laws of the State of California with its principal place of business at 303 East “B” Street, Ontario, California 91764-4196, County of San Bernardino, State of California ("City") and AppleOne, Inc., a Corporation, with its principal place of business at 1999 W. 190th Street, Torrance, CA 90504 ("Consultant"). City and Consultant are sometimes individually referred to herein as "Party" and collectively as "Parties."

2. RECITALS.

2.1 Consultant.

Consultant desires to perform and assume responsibility for the provision of certain professional services required by the City on the terms and conditions set forth in this Agreement.

Consultant represents that it is experienced in providing temporary staffing services to public clients, is licensed in the State of California, and is familiar with the plans of City.

2.2 Project.

City desires to engage Consultant to render such professional services for temporary staffing services for the City on an as-needed basis (“Project”) as set forth in this Agreement.

3. TERMS.

3.1 Scope of Services and Term.

3.1.1 General Scope of Services. Consultant promises and agrees to furnish to the City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the professional temporary staffing consulting services necessary for the Project ("Services"). The Services are more particularly described in Exhibit "A" attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordance with, this Agreement, the exhibits attached hereto and incorporated herein by reference, and all applicable local, state and federal laws, rules and regulations.

PAUL S. LEON
MAYOR

DEBRA PORADA

MAYOR PRO TEM
ALAN D. WAPNER
JIM W. BOWMAN

RUBEN VALENCIA

COUNCIL MEMBERS

SHEILA MAUTZ

CITY CLERK
JAMES R. MILHISER

TREASURER

SCOTT OCHOA

CITY MANAGER
773
46700.00100\40935195.1
BB&K (2023) -2- PROFESSIONAL SERVICES AGREEMENT

3.1.2 Term. The term of this Agreement shall be from November 21, 2023 to November 21, 2026, unless earlier terminated as provided herein. The City shall have the unilateral option, at its sole discretion, to renew this Agreement automatically for no more than two (2) additional one-year terms, unless earlier terminated as provided herein. Consultant shall complete the Services within the term of this Agreement and shall meet any other established schedules and deadlines. The Parties may, by mutual, written consent, extend the term of this Agreement if necessary to complete the Services.

3.2 Compensation.

3.2.1 Compensation. Consultant shall receive compensation, including authorized reimbursements, for all Services rendered under this Agreement at the rates set forth in Exhibit "C" attached hereto and incorporated herein by reference. The total compensation shall not exceed Seven Hundred Thousand Dollars and Zero Cents ($700,000) without written approval of the City Council or City Manager, as applicable. Extra Work may be authorized, as described below, and if authorized, will be compensated at the rates and manner set forth in this Agreement.

3.2.2 Payment of Compensation. Consultant shall submit to City a monthly invoice which indicates work completed and hours of Services rendered by Consultant. The invoice shall describe the amount of Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the invoice.

City shall, within 30 days of receiving such invoice, review the invoice and pay all non-disputed and approved charges. If the City disputes any of Consultant's fees, the City shall give written notice to Consultant within thirty (30) days of receipt of an invoice of any disputed fees set forth therein. Payment shall not constitute acceptance of any Services completed by Consultant. The making of final payment shall not constitute a waiver of any claims by the City for any reason whatsoever.

3.2.3 Reimbursement for Expenses. Consultant shall not be reimbursed for any expenses unless authorized in writing by City, or included in Exhibit "C" of this Agreement.

3.2.4 Extra Work. At any time during the term of this Agreement, City may request that Consultant perform Extra Work. As used herein, "Extra Work" means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement.

Consultant shall not perform, nor be compensated for, Extra Work without written authorization from the City.

3.3 Responsibilities of Consultant.

3.3.1 Independent Contractor; Control and Payment of Subordinates. The Services shall be performed by Consultant or under its supervision. Consultant will determine the means, methods and details of performing the Services subject to the requirements of this Agreement. City retains Consultant on an independent contractor basis and not as an employee.

Any personnel performing the Services on behalf of Consultant shall not be employees of City and shall at all times be under Consultant's exclusive direction and control. Neither City, or any of its officials, officers, directors, employees or agents shall have control over the conduct of Consultant or any of Consultants officers, employees or agents, except as set forth in this Agreement. Consultant shall pay all wages, salaries, and other amounts due such personnel in 774
46700.00100\40935195.1
BB&K (2023) -3- PROFESSIONAL SERVICES AGREEMENT
connection with their performance of Services under this Agreement and as required by law.

Consultant shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers' compensation insurance.

3.3.2 Schedule of Services. Consultant shall perform the Services in a prompt and timely manner and in accordance with the Schedule of Services set forth in Exhibit "B" attached hereto and incorporated herein by reference. Consultant represents that it has the professional and technical personnel required to perform the Services expeditiously. Upon request of City, Consultant shall provide a more detailed schedule of anticipated performance to meet the Schedule of Services.

3.3.3 Conformance to Applicable Requirements. All work prepared by Consultant shall be subject to the approval of City.

3.3.4 Substitution of Key Personnel. Consultant has represented to City that certain key personnel will perform and coordinate the Services under this Agreement. Should one or more of such personnel become unavailable, Consultant may substitute other personnel of at least equal competence upon written approval of City. In the event that City and Consultant cannot agree as to the substitution of key personnel, City shall be entitled to terminate this Agreement for cause. The key personnel for performance of this Agreement are as follows:

Milton J. Perkins, Vice President.

3.3.5 City's Representative. The City hereby designates Angela Lopez, Executive Director Human Resources/Risk Management, or his/her designee, to act as its representative in all matters pertaining to the administration and performance of this Agreement ("City's Representative"). City's Representative shall have the power to act on behalf of the City for review and approval of all products submitted by Consultant but not the authority to enlarge the Scope of Services or change the total compensation due to Consultant under this Agreement.

The City Manager shall be authorized to act on City's behalf and to execute all necessary documents which enlarge the Scope of Services or change the Consultant's total compensation subject to the provisions contained in this Agreement. Consultant shall not accept direction or orders from any person other than the City Manager, City's Representative or his/her designee.

3.3.6 Consultant's Representative. Consultant hereby designates Milton J.

Perkins, Vice President, or his/her designee, to act as its representative for the performance of this Agreement ("Consultant's Representative"). Consultant's Representative shall have full authority to represent and act on behalf of the Consultant for all purposes under this Agreement.

The Consultant's Representative shall supervise and direct the Services, using his/her best skill and attention, and shall be responsible for all means, methods, techniques, sequences, and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.

3.3.7 Coordination of Services. Consultant agrees to work closely with City staff in the performance of Services and shall be available to City's staff, consultants and other staff at all reasonable times.

3.3.8 Standard of Care; Performance of Employees. Consultant shall perform all Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals in the same discipline in the State of 775
46700.00100\40935195.1
BB&K (2023) -4- PROFESSIONAL SERVICES AGREEMENT
California. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services. Consultant warrants that all employees and subconsultants shall have sufficient skill and experience to perform the Services assigned to them. Consultant represents that it, its employees and subconsultants have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services, and that such licenses and approvals shall be maintained throughout the term of this Agreement. Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant's failure to comply with the standard of care provided for herein. Any employee of the Consultant or its subconsultants who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed from the Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.

3.3.9 Period of Performance.

3.3.9.1 Consultant shall perform and complete all Services under this Agreement within the term set forth in Section 3.1.2 above (“Performance Time”). Consultant shall also perform the Services in strict accordance with any completion schedule or Project milestones described in Exhibits “A” or “B” attached hereto, or which may be separately agreed upon in writing by the City and Consultant (“Performance Milestones”). Consultant agrees that if the Services are not completed within the aforementioned Performance Time and/or pursuant to any such Performance Milestones developed pursuant to provisions of this Agreement, it is understood, acknowledged and agreed that the City will suffer damage.

3.3.9.2 Neither City nor Consultant shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the non-performing Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Consultant and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the services and Agreement.

3.3.9.3 Should a Force Majeure Event occur, the non-performing Party shall, within a reasonable time of being prevented from performing, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events and/or delays, regardless of the Party responsible for the delay, shall not entitle Consultant to any additional compensation.

Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement. 776
46700.00100\40935195.1
BB&K (2023) -5- PROFESSIONAL SERVICES AGREEMENT

3.3.10 Laws and Regulations; Employee/Labor Certification.

3.3.10.1 Compliance with Laws. Consultant shall keep itself fully informed of and in compliance with all local, state and federal laws, rules and regulations in any manner affecting the performance of the Project or the Services, including all Cal/OSHA requirements, and shall give all notices required by law. Consultant shall be liable for all violations of such laws and regulations in connection with the Services and this Agreement. All violations of such laws and regulations shall be grounds for the City to terminate the Agreement for cause.

3.3.10.2 Employment Eligibility; Consultant. Consultant certifies that it fully complies with all requirements and restrictions of state and federal law respecting the employment of undocumented aliens, including, but not limited to, the Immigration Reform and Control Act of 1986, as may be amended from time to time and shall require all subconsultants and sub-subconsultants to comply with the same. Consultant certifies that it has not committed a violation of any such law within the five (5) years immediately preceding the date of execution of this Agreement, and shall not violate any such law at any time during the term of the Agreement.

3.3.10.3 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subconsultant, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination. Consultant shall also comply with all relevant provisions of City's Minority Business Enterprise program, Affirmative Action Plan or other related programs or guidelines currently in effect or hereinafter enacted.

3.3.10.4 Air Quality. To the extent applicable, Consultant must fully comply with all applicable laws, rules and regulations in furnishing or using equipment and/or providing services, including, but not limited to, emissions limits and permitting requirements imposed by the South Coast Air Quality Management District (SCAQMD) and/or California Air Resources Board (CARB). Consultant shall indemnify City against any fines or penalties imposed by SCAQMD, CARB, or any other governmental or regulatory agency for violations of applicable laws, rules and/or regulations by Consultant, its subconsultants, or others for whom Consultant is responsible under its indemnity obligations provided for in this Agreement.

3.3.10.5 Water Quality Management and Compliance. Consultant shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Services including, without limitation, all applicable provisions of the City’s ordinances regulating water quality and storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251, et seq.); the California Porter-Cologne Water Quality Control Act (Water Code § 13000 et seq.); and any and all regulations, policies, or permits issued pursuant to any such authority. Consultant must additionally comply with the lawful requirements of the City, and any other municipality, drainage district, or other local agency with jurisdiction over the location where the Services are to be conducted, regulating water quality and storm water discharges. City may seek damages from Consultant for delay in completing the Services caused by Consultant’s failure to comply with the laws, regulations and policies described in this Section, or any other relevant water quality law, regulation, or policy.
777
46700.00100\40935195.1
BB&K (2023) -6- PROFESSIONAL SERVICES AGREEMENT

3.3.10.6 Safety. Consultant shall execute and maintain its work so as to avoid injury or damage to any person or property. In carrying out its Services, the Consultant shall at all times be in compliance with all applicable local, state and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of employees appropriate to the nature of the work and the conditions under which the work is to be performed.

3.3.11 Insurance.

3.3.11.1 Time for Compliance. Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurance required under this section. Failure to provide and maintain all required insurance shall be grounds for the City to terminate this Agreement for cause.

3.3.11.2 Types of Insurance Required. As a condition precedent to the effectiveness of this Agreement for work to be performed hereunder, and without limiting the indemnity provisions of the Agreement, the Consultant, in partial performance of its obligations under such Agreement, shall procure and maintain in full force and effect during the term of the Agreement the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Consultant agrees to amend, supplement or endorse the policies to do so.
(A) Commercial General Liability: Commercial General Liability Insurance which affords coverage at least as broad as Insurance Services Office "occurrence" form CG 00 01, or the exact equivalent, with limits of not less than $2,000,000 per occurrence and no less than $4,000,000 in the general aggregate. Defense costs shall be paid in addition to the limits. The policy shall contain no endorsements or provisions (1) limiting coverage for contractual liability; (2) excluding coverage for claims or suits by one insured against another (cross-liability); (3) products/completed operations liability; or (4) containing any other exclusion(s) contrary to the terms or purposes of this Agreement. (B) Automobile Liability Insurance: Automobile Liability Insurance with coverage at least as broad as Insurance Services Office Form CA 00 01 covering "Any Auto" (Symbol 1), or the exact equivalent, covering bodily injury and property damage for all activities with limits of not less than $2,000,000 combined limit for each occurrence. (C) Workers' Compensation: Workers' Compensation
Insurance, as required by the State of California and Employer's Liability Insurance with a limit of not less than $1,000,000 per accident for bodily injury and disease. (D) Professional Liability (Errors & Omissions): Professional Liability insurance or Errors & Omissions insurance appropriate to Consultant’s profession with limits of not less than $2,000,000. Covered professional services shall specifically include all work to be performed under the Agreement and delete any exclusions that may potentially affect the work to be performed (for example, any exclusions relating to lead, asbestos, pollution, testing, underground storage tanks, laboratory analysis, soil work, etc.). If coverage is written on a claims-made basis, the retroactive date shall precede the effective date of the initial Agreement and continuous coverage will be maintained or an extended reporting period will be exercised for a period of at least five (5) years from termination or expiration of this Agreement. 778
46700.00100\40935195.1
BB&K (2023) -7- PROFESSIONAL SERVICES AGREEMENT

3.3.11.3 Insurance Endorsements. Required insurance policies shall contain the following provisions, or Consultant shall provide endorsements on forms approved by the City to add the following provisions to the insurance policies:
(A) Commercial General Liability: (1) Additional Insured: The City, its officials, officers, employees, agents, and volunteers shall be additional insureds with regard to liability and defense of suits or claims arising out of the performance of the Agreement.

Additional Insured Endorsements shall not (1) be restricted to "ongoing operations"; (2) exclude "contractual liability"; (3) restrict coverage to "sole" liability of Consultant; or (4) contain any other exclusions contrary to the terms or purposes of this Agreement. For all policies of Commercial General Liability insurance, Consultant shall provide endorsements in the form of ISO CG 20 10 10 01 and 20 37 10 01 (or endorsements providing the exact same coverage) to effectuate this requirement. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (B) Automobile Liability: (1) Additional Insured: The City, its directors, officials, officers, employees, agents, and volunteers shall be covered as additional insureds with respect to the ownership, operation, maintenance, use, loading or unloading of any auto owned, leased, hired or borrowed by the Vendor or for which the Vendor is responsible. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium.
(C) Professional Liability (Errors & Omissions): 1) Cancellation:

Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) This insurance shall be written on a policy form coverage specifically designed to protect against acts, errors or omissions of the Consultant. “Covered Professional Services” as designated in the policy must specifically include work performed under this Agreement. The policy must “pay on behalf of” the insured and include a provision establishing the insurer’s duty to defend.
(D) Workers' Compensation: (1) Cancellation: Required
insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) Waiver of Subrogation: A waiver of subrogation stating that the insurer waives all rights of subrogation against the City, its officials, officers, employees, agents, and volunteers.

3.3.11.4 Primary and Non-Contributing Insurance. All policies of Commercial General Liability and Automobile Liability insurance shall be primary and any other insurance, deductible, or self-insurance maintained by the City, its officials, officers, employees, agents, or volunteers shall not contribute with this primary insurance. Policies shall contain or be endorsed to contain such provisions.

3.3.11.5 Waiver of Subrogation. All required insurance coverages, except for the professional liability coverage, shall contain or be endorsed to waiver of subrogation in favor of the City, its officials, officers, employees, agents, and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these specifications 779
46700.00100\40935195.1
BB&K (2023) -8- PROFESSIONAL SERVICES AGREEMENT
to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants.

3.3.11.6 Deductibles and Self-Insured Retentions. Any deductible or selfinsured retention must be approved in writing by the City and shall protect the City, its officials, officers, employees, agents, and volunteers in the same manner and to the same extent as they would have been protected had the policy or policies not contained a deductible or self-insured retention.

3.3.11.7 Evidence of Insurance. The Consultant, concurrently with the execution of the Agreement, and as a condition precedent to the effectiveness thereof, shall deliver either certified copies of the required policies, or original certificates on forms approved by the City, together with all endorsements affecting each policy. Required insurance policies shall not be in compliance if they include any limiting provision or endorsement that has not been submitted to the City for approval. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf. At least fifteen (15 days) prior to the expiration of any such policy, evidence of insurance showing that such insurance coverage has been renewed or extended shall be filed with the City. If such coverage is cancelled or reduced and not replaced immediately so as to avoid a lapse in the required coverage, Consultant shall, within ten (10) days after receipt of written notice of such cancellation or reduction of coverage, file with the City evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies.

3.3.11.8 Acceptability of Insurers. Each such policy shall be from a company or companies with a current A.M. Best's rating of no less than A:VII and authorized to transact business of insurance in the State of California, or otherwise allowed to place insurance through surplus line brokers under applicable provisions of the California Insurance Code or any federal law.

3.3.11.9 Enforcement of Agreement Provisions (non estoppel).

Consultant acknowledges and agrees that actual or alleged failure on the part of the City to inform Consultant of non-compliance with any requirement imposes no additional obligation on the City nor does it waive any rights hereunder.

3.3.11.10 Requirements Not Limiting. Requirement of specific coverage or minimum limits contained in this Section are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance.

3.3.11.11 Additional Insurance Provisions
(A) The foregoing requirements as to the types and limits of insurance coverage to be maintained by Consultant, and any approval of said insurance by the City, is not intended to and shall not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Consultant pursuant to this Agreement, including but not limited to, the provisions concerning indemnification.
(B) If at any time during the life of the Agreement, any policy of insurance required under this Agreement does not comply with these specifications or is canceled 780
46700.00100\40935195.1
BB&K (2023) -9- PROFESSIONAL SERVICES AGREEMENT
and not replaced, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Consultant or City will withhold amounts sufficient to pay premium from Consultant payments. In the alternative, City may cancel this Agreement.
(C) The City may require the Consultant to provide complete copies of all insurance policies in effect for the duration of the Project. (D) Neither the City nor any of its officials, officers, employees, agents or volunteers shall be personally responsible for any liability arising under or by virtue of this Agreement.
(E) The limits set forth herein shall apply separately to each insured against whom claims are made or suits are brought, except with respect to the limits of liability. Further the limits set forth herein shall not be construed to relieve the Consultant from liability in excess of such coverage, nor shall it limit the Consultant’s indemnification obligations to the City and shall not preclude the City from taking such other actions available to the City under other provisions of the Agreement or law.
(F) Consultant shall report to the City, in addition to Consultant’s insurer, any and all insurance claims submitted by Consultant in connection with the Services under this Agreement.

3.3.11.12 Insurance for Subconsultants. Consultant shall include all subconsultants engaged in any work for Consultant relating to this Agreement as additional insureds under the Consultant's policies, or the Consultant shall be responsible for causing subconsultants to purchase the appropriate insurance in compliance with the terms of these Insurance Requirements, including adding the City, its officials, officers, employees, agents, and volunteers as additional insureds to the subconsultant's policies. All policies of Commercial General Liability insurance provided by Consultant’s subconsultants performing work relating to this Agreement shall be endorsed to name the City, its officials, officers, employees, agents and volunteers as additional insureds using endorsement form ISO CG 20 38 04 13 or an endorsement providing equivalent coverage. Consultant shall not allow any subconsultant to commence work on any subcontract relating to this Agreement until it has received satisfactory evidence of subconsultant’s compliance with all insurance requirements under this Agreement, to the extent applicable. The Consultant shall provide satisfactory evidence of compliance with this section upon request of the City.

3.4 Labor Code Requirements.

3.4.1 Prevailing Wages. Consultant is aware of the requirements of California Labor Code Section 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., ("Prevailing Wage Laws"), which require the payment of prevailing wage rates and the performance of other requirements on "public works" and "maintenance" projects. If the Services are being performed as part of an applicable "public works" or "maintenance" project, as defined by the Prevailing Wage Laws, and if the total compensation is $1,000 or more, Consultant agrees to fully comply with such Prevailing Wage Laws. City shall provide Consultant with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Consultant shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services 781
46700.00100\40935195.1
BB&K (2023) -10- PROFESSIONAL SERVICES AGREEMENT
available to interested parties upon request, and shall post copies at the Consultant's principal place of business and at the project site. It is the intent of the parties to effectuate the requirements of sections 1771, 1774, 1775, 1776, 1777.5, 1813, and 1815 of the Labor Code within this Agreement, and Consultant shall therefore comply with such Labor Code sections to the fullest extent required by law. Consultant shall defend, indemnify and hold the City, its officials, officers, employees, agents, and volunteers free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws.

3.4.2 Registration/DIR Compliance. If the Services are being performed on a public works project of over $25,000 when the project is for construction, alteration, demolition, installation, or repair work, or a public works project of over $15,000 when the project is for maintenance work, in addition to the foregoing, then pursuant to Labor Code sections 1725.5 and 1771.1, the Consultant and all subconsultants must be registered with the Department of Industrial Relations (“DIR”). Consultant shall maintain registration for the duration of the Project and require the same of any subconsultants.

3.4.3 Compliance Monitoring. This Project may also be subject to compliance monitoring and enforcement by the DIR. It shall be Consultant’s sole responsibility to comply with all applicable registration and labor compliance requirements, including the submission of payroll records directly to the DIR. Any stop orders issued by the DIR against Consultant or any subconsultant that affect Consultant’s performance of services, including any delay, shall be Consultant’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Consultant caused delay and shall not be compensable by the City. Consultant shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the DIR against Consultant or any subconsultant.

3.4.4 Labor Certification. By its signature hereunder, Consultant certifies that it is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker's Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services.

3.5 Termination of Agreement.

3.5.1.1 Grounds for Termination. City may, by written notice to Consultant, terminate the whole or any part of this Agreement at any time and without cause by giving written notice to Consultant of such termination, and specifying the effective date thereof, at least seven (7) days before the effective date of such termination. Upon termination, Consultant shall be compensated only for those Services which have been adequately rendered to City, and Consultant shall be entitled to no further compensation. Consultant may not terminate this Agreement except for cause. The rights and remedies of the City provided in this section shall not be exclusive and are in addition to any other rights and remedies provided by law, equity or under this Agreement.

3.5.1.2 Effect of Termination. If this Agreement is terminated as provided herein, City may require Consultant to provide all finished or unfinished Documents and Data and other information of any kind prepared by Consultant in connection with the performance of Services under this Agreement. Consultant shall be required to provide such document and other information within fifteen (15) days of the request. 782
46700.00100\40935195.1
BB&K (2023) -11- PROFESSIONAL SERVICES AGREEMENT

3.5.1.3 Additional Services. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated.

3.6 Indemnification.

3.6.1 To the fullest extent permitted by law, Consultant shall defend (with counsel of City’s choosing), indemnify and hold the City, its officials, officers, employees, volunteers, and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Consultant, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Consultant’s Services, the Project or this Agreement, including without limitation the payment of all damages, expert witness fees and attorney’s fees and other related costs and expenses except such loss or damage caused by the sole negligence or willful misconduct of the City. Consultant's obligation to indemnify shall survive expiration or termination of this Agreement and shall not be restricted to insurance proceeds, if any, received by Consultant, the City, its officials, officers, employees, agents, or volunteers.

3.6.2 If Consultant’s obligation to defend, indemnify, and/or hold harmless arises out of Consultant’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Consultant’s indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Consultant, and, upon Consultant obtaining a final adjudication by a court of competent jurisdiction, Consultant’s liability for such claim, including the cost to defend, shall not exceed the Consultant’s proportionate percentage of fault.

3.7 General Provisions.

3.7.1 Accounting Records. Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to this Agreement. Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement.

3.7.2 Independent Contractors and Subcontracting.

3.7.2.1 Use of Consultants. Consultant is aware of statutory and case law regarding classification of workers as independent contractors, including California Labor Code Section 2750.3 and Dynamex Operations West, Inc. v. Superior Court, 4 Cal. 5th 903 (2018). To ensure that Consultant is in compliance with the California Labor Code, Consultant shall only utilize its employees to provide the Services. Consultant may not provide the services through any independent contractor, subcontractor or subconsultant (“Subcontractor(s)”) unless approved by the City as set forth in Section 3.7.2.2 below. Consultant represents and warrants that all personnel who perform the Services on Consultant’s behalf are Consultant’s employees, and that Consultant complies with all applicable laws, rules and regulations governing its 783
46700.00100\40935195.1
BB&K (2023) -12- PROFESSIONAL SERVICES AGREEMENT
employees, including, but not limited to, the California Labor Code, Unemployment Insurance Code and all applicable Industrial Welfare Commission Wage Orders.

3.7.2.2 Prior Approval Required. Consultant shall not use any Subcontractor to provide the Services, or any portion of the work required by this Agreement, without prior written approval of City. In the event that City authorizes Consultant to use a Subcontractor, Consultant shall enter into a written agreement with the Subcontractor, which must include all provisions of the Agreement, including a restriction on the Subcontractor’s use of further independent contractors, subcontractors or subconsultants without the City’s prior written consent.

3.7.3 Delivery of Notices. All notices permitted or required under this Agreement shall be given to the respective parties at the following address, or at such other address as the respective parties may provide in writing for this purpose:

Consultant: AppleOne, Inc.
1999 W. 190th Street
Torrance, CA 90504
ATTN: Milton J. Perkins, Vice President
City: City of Ontario
303 East “B” Street
Ontario, CA 91764
ATTN: Angela Lopez, Executive Director Human
Resources/Risk Management
Such notice shall be deemed made when personally delivered or when mailed, forty-eight (48) hours after deposit in the U.S. Mail, first class postage prepaid and addressed to the party at its applicable address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.

3.7.4 Ownership of Materials and Confidentiality.

3.7.4.1 Documents & Data; Licensing of Intellectual Property. This Agreement creates a non-exclusive and perpetual license for City to copy, use, modify, reuse, or sublicense any and all copyrights, designs, and other intellectual property embodied in plans, specifications, studies, drawings, estimates, and other documents or works of authorship fixed in any tangible medium of expression, including but not limited to, physical drawings or data magnetically or otherwise recorded on computer diskettes, which are prepared or caused to be prepared by Consultant under this Agreement ("Documents & Data"). All Documents & Data shall be and remain the property of City, and shall not be used in whole or in substantial part by Consultant on other projects without the City’s express written permission. Within thirty (30) days following the completion, suspension, abandonment or termination of this Agreement, Consultant shall provide to City reproducible copies of all Documents & Data, in a form and amount required by City. City reserves the right to select the method of document reproduction and to establish where the reproduction will be accomplished. The reproduction expense shall be borne by City at the actual cost of duplication. In the event of a dispute regarding the amount of compensation to which the Consultant is entitled under the termination provisions of this Agreement, Consultant shall provide all Documents & Data to City upon payment of the undisputed amount. Consultant shall have no right to retain or fail to provide to City any such documents pending resolution of 784
46700.00100\40935195.1
BB&K (2023) -13- PROFESSIONAL SERVICES AGREEMENT
the dispute. In addition, Consultant shall retain copies of all Documents & Data on file for a minimum of fifteen (15) years following completion of the Project, and shall make copies available to City upon the payment of actual reasonable duplication costs. Before destroying the Documents & Data following this retention period, Consultant shall make a reasonable effort to notify City and provide City with the opportunity to obtain the documents.

3.7.4.2 Subconsultants. Consultant shall require all subconsultants to agree in writing that City is granted a non-exclusive and perpetual license for any Documents & Data the subconsultant prepares under this Agreement. Consultant represents and warrants that Consultant has the legal right to license any and all Documents & Data. Consultant makes no such representation and warranty in regard to Documents & Data which were prepared by design professionals other than Consultant or its subconsultants, or those provided to Consultant by the City.

3.7.4.3 Right to Use. City shall not be limited in any way in its use or reuse of the Documents and Data or any part of them at any time for purposes of this Project or another project, provided that any such use not within the purposes intended by this Agreement or on a project other than this Project without employing the services of Consultant shall be at City’s sole risk. If City uses or reuses the Documents & Data on any project other than this Project, it shall remove the Consultant’s seal from the Documents & Data and indemnify and hold harmless Consultant and its officers, directors, agents and employees from claims arising out of the negligent use or re-use of the Documents & Data on such other project. Consultant shall be responsible and liable for its Documents & Data, pursuant to the terms of this Agreement, only with respect to the condition of the Documents & Data at the time they are provided to the City upon completion, suspension, abandonment or termination. Consultant shall not be responsible or liable for any revisions to the Documents & Data made by any party other than Consultant, a party for whom the Consultant is legally responsible or liable, or anyone approved by the Consultant.

3.7.4.4 Indemnification. Consultant shall defend, indemnify and hold the City, its directors, officials, officers, employees, volunteers and agents free and harmless, pursuant to the indemnification provisions of this Agreement, for any alleged infringement of any patent, copyright, trade secret, trade name, trademark, or any other proprietary right of any person or entity in consequence of the use on the Project by City of the Documents & Data, including any method, process, product, or concept specified or depicted.

3.7.4.5 Confidentiality. All ideas, memoranda, specifications, plans, procedures, drawings, descriptions, computer program data, input record data, written information, and other Documents & Data either created by or provided to Consultant in connection with the performance of this Agreement shall be held confidential by Consultant. Such materials shall not, without the prior written consent of City, be used by Consultant for any purposes other than the performance of the Services. Nor shall such materials be disclosed to any person or entity not connected with the performance of the Services or the Project. Nothing furnished to Consultant which is otherwise known to Consultant or is generally known, or has become known, to the related industry shall be deemed confidential. Consultant shall not use City's name or insignia, photographs of the Project, or any publicity pertaining to the Services or the Project in any magazine, trade paper, newspaper, television or radio production or other similar medium without the prior written consent of City. 785
46700.00100\40935195.1
BB&K (2023) -14- PROFESSIONAL SERVICES AGREEMENT

3.7.4.6 Confidential Information. The City shall refrain from releasing Consultant’s proprietary information ("Proprietary Information") unless the City's legal counsel determines that the release of the Proprietary Information is required by the California Public Records Act or other applicable state or federal law, or order of a court of competent jurisdiction, in which case the City shall notify Consultant of its intention to release Proprietary Information.

Consultant shall have five (5) working days after receipt of the release notice to give City written notice of Consultant's objection to the City's release of Proprietary Information. Consultant shall indemnify, defend and hold harmless the City, and its officers, directors, employees, and agents from and against all liability, loss, cost or expense (including attorney’s fees) arising out of a legal action brought to compel the release of Proprietary Information. City shall not release the Proprietary Information after receipt of an objection notice unless either: (1) Consultant fails to fully indemnify, defend (with City's choice of legal counsel), and hold City harmless from any legal action brought to compel such release; and/or (2) a final and non-appealable order by a court of competent jurisdiction requires that City release such information.

3.7.5 Cooperation; Further Acts. The Parties shall fully cooperate with one another, and shall take any additional acts or sign any additional documents as may be necessary, appropriate or convenient to attain the purposes of this Agreement.

3.7.6 Entire Agreement. This Agreement contains the entire agreement of the Parties with respect to the subject matter hereof, and supersedes all prior negotiations, understandings or agreements.

3.7.7 Attorneys’ Fees. If either party commences an action against the other party, either legal, administrative or otherwise, arising out of or in connection with this Agreement, the prevailing party in such litigation shall be entitled to have and recover from the losing party reasonable attorneys’ fees and all costs of such action.

3.7.8 Governing Law. This Agreement shall be governed by the laws of the State of California. Venue shall be in San Bernardino County. In addition to any and all contract requirements pertaining to notices of and requests for compensation or payment for extra work, disputed work, claims and/or changed conditions, Consultant must comply with the claim procedures set forth in Government Code sections 900 et seq. prior to filing any lawsuit against the City. Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to extra work, disputed work, claims, and/or changed conditions have been followed by Consultant. If no such Government Code claim is submitted, or if any prerequisite contractual requirements are not otherwise satisfied as specified herein, Consultant shall be barred from bringing and maintaining a valid lawsuit against the City.

3.7.9 Time of Essence. Time is of the essence for each and every provision of this Agreement.

3.7.10 City's Right to Employ Other Consultants. City reserves right to employ other consultants in connection with this Project.

3.7.11 Successors and Assigns. This Agreement shall be binding on the successors and assigns of the parties.

3.7.12 Assignment or Transfer. Consultant shall not assign, sublet, or transfer this 786
46700.00100\40935195.1
BB&K (2023) -15- PROFESSIONAL SERVICES AGREEMENT
Agreement or any rights under or interest in this Agreement without the written consent of the City, which may be withheld for any reason. Any attempt to so assign or so transfer without such consent shall be void and without legal effect and shall constitute grounds for termination.

Consultant shall not subcontract any portion of the Services required by this Agreement, except as expressly stated herein, without prior written approval of City. Subcontracts, if any, shall contain a provision making them subject to all provisions stipulated in this Agreement.

3.7.13 Construction; References; Captions. Since the Parties or their agents have participated fully in the preparation of this Agreement, the language of this Agreement shall be construed simply, according to its fair meaning, and not strictly for or against any Party. Any term referencing time, days or period for performance shall be deemed calendar days and not work days. All references to Consultant include all personnel, employees, agents, and subconsultants of Consultant, except as otherwise specified in this Agreement. All references to City include its elected officials, officers, employees, agents, and volunteers except as otherwise specified in this Agreement. The captions of the various articles and paragraphs are for convenience and ease of reference only, and do not define, limit, augment, or describe the scope, content, or intent of this Agreement.

3.7.14 Amendment; Modification. No supplement, modification, or amendment of this Agreement shall be binding unless executed in writing and signed by both Parties.

3.7.15 Waiver. No waiver of any default shall constitute a waiver of any other default or breach, whether of the same or other covenant or condition. No waiver, benefit, privilege, or service voluntarily given or performed by a Party shall give the other Party any contractual rights by custom, estoppel, or otherwise.

3.7.16 No Third-Party Beneficiaries. There are no intended third party beneficiaries of any right or obligation assumed by the Parties.

3.7.17 Invalidity; Severability. If any portion of this Agreement is declared invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect.

3.7.18 Prohibited Interests. Consultant maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Consultant, to solicit or secure this Agreement. Consultant warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. Consultant further agrees to file, or shall cause its employees or subconsultants to file, a Statement of Economic Interest with the City’s Filing Officer as required under state law in the performance of the Services. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability. For the term of this Agreement, no member, officer or employee of City, during the term of his or her service with City, shall have any direct interest in this Agreement, or obtain any present or anticipated material benefit arising therefrom.

3.7.19 Authority to Enter Agreement. Consultant has all requisite power and authority to conduct its business and to execute, deliver, and perform the Agreement. Each Party warrants that the individuals who have signed this Agreement have the legal power, right, and authority to make this Agreement and bind each respective Party. 787
46700.00100\40935195.1
BB&K (2023) -16- PROFESSIONAL SERVICES AGREEMENT

3.7.20 Counterparts. This Agreement may be signed in counterparts, each of which shall constitute an original.

3.7.21 Survival. All rights and obligations hereunder that by their nature are to continue after any expiration or termination of this Agreement, including, but not limited to, the indemnification obligations, shall survive any such expiration or termination.

SIGNATURES ON NEXT PAGE
788
46700.00100\40935195.1
BB&K (2023) -17- PROFESSIONAL SERVICES AGREEMENT

SIGNATURE PAGE TO PROFESSIONAL SERVICES AGREEMENT

BETWEEN THE CITY OF ONTARIO AND
AppleOne, Inc.

IN WITNESS WHEREOF, each of the Parties has caused this Agreement to be executed on the day and year first above written.

CITY OF ONTARIO AppleOne, Inc.

By: AAA
Its: BBB
Printed Name: CCC
By: DDD
Its: EEE
Printed Name: FFF
[If Corporation, TWO SIGNATURES,
President OR Vice President AND Secretary
OR Treasurer REQUIRED]
Approved By:

Scott Ochoa
City Manager
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:

City Clerk
789
46700.00100\40935195.1
BB&K (2023) Exhibit “A”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "A"

SCOPE OF SERVICES

PROPOSED SCOPE OF SERVICES
790
46700.00100
\40935195.1
BB&K (2023) Exhibit “A-I-1” PROFESSIONAL SERVICES AGREEMENT 791
46700.00100\40935195.1
BB&K (2023) Exhibit “B”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "B"

SCHEDULE OF SERVICES
792
46700.00100\40935195.1
BB&K (2023) Exhibit “C”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "C"

COMPENSATION
793
46700.00100\40935195.1
BB&K (2023) Exhibit “C”-1 PROFESSIONAL SERVICES AGREEMENT

CITY OF ONTARIO

PROFESSIONAL SERVICES AGREEMENT

1. PARTIES AND DATE.

This Agreement is made and entered as of ____________, by and between the City of Ontario, a municipal corporation organized under the laws of the State of California with its principal place of business at 303 East “B” Street, Ontario, California 91764-4196, County of San Bernardino, State of California ("City") and Enterprise Solutions, Inc., a Corporation, with its principal place of business at 5201 Great America Parkway, Suite 320, Santa Clara, CA 95054 ("Consultant"). City and Consultant are sometimes individually referred to herein as "Party" and collectively as "Parties."

2. RECITALS.

2.1 Consultant.

Consultant desires to perform and assume responsibility for the provision of certain professional services required by the City on the terms and conditions set forth in this Agreement.

Consultant represents that it is experienced in providing temporary staffing services to public clients, is licensed in the State of California, and is familiar with the plans of City.

2.2 Project.

City desires to engage Consultant to render such professional services for temporary staffing services for the City on an as-needed basis (“Project”) as set forth in this Agreement.

3. TERMS.

3.1 Scope of Services and Term.

3.1.1 General Scope of Services. Consultant promises and agrees to furnish to the City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the professional temporary staffing consulting services necessary for the Project ("Services"). The Services are more particularly described in Exhibit "A" attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordance with, this Agreement, the exhibits attached hereto and incorporated PAUL S. LEON
MAYOR

DEBRA PORADA

MAYOR PRO TEM
ALAN D. WAPNER
JIM W. BOWMAN

RUBEN VALENCIA

COUNCIL MEMBERS

SHEILA MAUTZ

CITY CLERK
JAMES R. MILHISER

TREASURER

SCOTT OCHOA

CITY MANAGER
794
46700.00100\40935195.1
BB&K (2023) -2- PROFESSIONAL SERVICES AGREEMENT
herein by reference, and all applicable local, state and federal laws, rules and regulations.

3.1.2 Term. The term of this Agreement shall be from November 21, 2023 to November 21, 2026, unless earlier terminated as provided herein. The City shall have the unilateral option, at its sole discretion, to renew this Agreement automatically for no more than two (2) additional one-year terms, unless earlier terminated as provided herein. Consultant shall complete the Services within the term of this Agreement and shall meet any other established schedules and deadlines. The Parties may, by mutual, written consent, extend the term of this Agreement if necessary to complete the Services.

3.2 Compensation.

3.2.1 Compensation. Consultant shall receive compensation, including authorized reimbursements, for all Services rendered under this Agreement at the rates set forth in Exhibit "C" attached hereto and incorporated herein by reference. The total compensation shall not exceed Seven Hundred Thousand Dollars and Zero Cents ($700,000) without written approval of the City Council or City Manager, as applicable. Extra Work may be authorized, as described below, and if authorized, will be compensated at the rates and manner set forth in this Agreement.

3.2.2 Payment of Compensation. Consultant shall submit to City a monthly invoice which indicates work completed and hours of Services rendered by Consultant. The invoice shall describe the amount of Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the invoice.

City shall, within 30 days of receiving such invoice, review the invoice and pay all non-disputed and approved charges. If the City disputes any of Consultant's fees, the City shall give written notice to Consultant within thirty (30) days of receipt of an invoice of any disputed fees set forth therein. Payment shall not constitute acceptance of any Services completed by Consultant. The making of final payment shall not constitute a waiver of any claims by the City for any reason whatsoever.

3.2.3 Reimbursement for Expenses. Consultant shall not be reimbursed for any expenses unless authorized in writing by City, or included in Exhibit "C" of this Agreement.

3.2.4 Extra Work. At any time during the term of this Agreement, City may request that Consultant perform Extra Work. As used herein, "Extra Work" means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement.

Consultant shall not perform, nor be compensated for, Extra Work without written authorization from the City.

3.3 Responsibilities of Consultant.

3.3.1 Independent Contractor; Control and Payment of Subordinates. The Services shall be performed by Consultant or under its supervision. Consultant will determine the means, methods and details of performing the Services subject to the requirements of this Agreement. City retains Consultant on an independent contractor basis and not as an employee.

Any personnel performing the Services on behalf of Consultant shall not be employees of City and shall at all times be under Consultant's exclusive direction and control. Neither City, or any of its officials, officers, directors, employees or agents shall have control over the conduct of 795
46700.00100\40935195.1
BB&K (2023) -3- PROFESSIONAL SERVICES AGREEMENT
Consultant or any of Consultants officers, employees or agents, except as set forth in this Agreement. Consultant shall pay all wages, salaries, and other amounts due such personnel in connection with their performance of Services under this Agreement and as required by law.

Consultant shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers' compensation insurance.

3.3.2 Schedule of Services. Consultant shall perform the Services in a prompt and timely manner and in accordance with the Schedule of Services set forth in Exhibit "B" attached hereto and incorporated herein by reference. Consultant represents that it has the professional and technical personnel required to perform the Services expeditiously. Upon request of City, Consultant shall provide a more detailed schedule of anticipated performance to meet the Schedule of Services.

3.3.3 Conformance to Applicable Requirements. All work prepared by Consultant shall be subject to the approval of City.

3.3.4 Substitution of Key Personnel. Consultant has represented to City that certain key personnel will perform and coordinate the Services under this Agreement. Should one or more of such personnel become unavailable, Consultant may substitute other personnel of at least equal competence upon written approval of City. In the event that City and Consultant cannot agree as to the substitution of key personnel, City shall be entitled to terminate this Agreement for cause. The key personnel for performance of this Agreement are as follows:

Sudesh Verma, Senior Proposal Manager.

3.3.5 City's Representative. The City hereby designates Angela Lopez, Executive Director Human Resources/Risk Management, or his/her designee, to act as its representative in all matters pertaining to the administration and performance of this Agreement ("City's Representative"). City's Representative shall have the power to act on behalf of the City for review and approval of all products submitted by Consultant but not the authority to enlarge the Scope of Services or change the total compensation due to Consultant under this Agreement.

The City Manager shall be authorized to act on City's behalf and to execute all necessary documents which enlarge the Scope of Services or change the Consultant's total compensation subject to the provisions contained in this Agreement. Consultant shall not accept direction or orders from any person other than the City Manager, City's Representative or his/her designee.

3.3.6 Consultant's Representative. Consultant hereby designates Sudesh Verma, Senior Proposal Manager, or his/her designee, to act as its representative for the performance of this Agreement ("Consultant's Representative"). Consultant's Representative shall have full authority to represent and act on behalf of the Consultant for all purposes under this Agreement. The Consultant's Representative shall supervise and direct the Services, using his/her best skill and attention, and shall be responsible for all means, methods, techniques, sequences, and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.

3.3.7 Coordination of Services. Consultant agrees to work closely with City staff in the performance of Services and shall be available to City's staff, consultants and other staff at all reasonable times.

3.3.8 Standard of Care; Performance of Employees. Consultant shall perform all 796
46700.00100\40935195.1
BB&K (2023) -4- PROFESSIONAL SERVICES AGREEMENT
Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals in the same discipline in the State of California. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services. Consultant warrants that all employees and subconsultants shall have sufficient skill and experience to perform the Services assigned to them. Consultant represents that it, its employees and subconsultants have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services, and that such licenses and approvals shall be maintained throughout the term of this Agreement. Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant's failure to comply with the standard of care provided for herein. Any employee of the Consultant or its subconsultants who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed from the Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.

3.3.9 Period of Performance.

3.3.9.1 Consultant shall perform and complete all Services under this Agreement within the term set forth in Section 3.1.2 above (“Performance Time”). Consultant shall also perform the Services in strict accordance with any completion schedule or Project milestones described in Exhibits “A” or “B” attached hereto, or which may be separately agreed upon in writing by the City and Consultant (“Performance Milestones”). Consultant agrees that if the Services are not completed within the aforementioned Performance Time and/or pursuant to any such Performance Milestones developed pursuant to provisions of this Agreement, it is understood, acknowledged and agreed that the City will suffer damage.

3.3.9.2 Neither City nor Consultant shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the non-performing Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Consultant and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the services and Agreement.

3.3.9.3 Should a Force Majeure Event occur, the non-performing Party shall, within a reasonable time of being prevented from performing, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events and/or delays, regardless of the Party responsible for the delay, shall not entitle Consultant to any additional compensation. 797
46700.00100\40935195.1
BB&K (2023) -5- PROFESSIONAL SERVICES AGREEMENT
Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement.

3.3.10 Laws and Regulations; Employee/Labor Certification.

3.3.10.1 Compliance with Laws. Consultant shall keep itself fully informed of and in compliance with all local, state and federal laws, rules and regulations in any manner affecting the performance of the Project or the Services, including all Cal/OSHA requirements, and shall give all notices required by law. Consultant shall be liable for all violations of such laws and regulations in connection with the Services and this Agreement. All violations of such laws and regulations shall be grounds for the City to terminate the Agreement for cause.

3.3.10.2 Employment Eligibility; Consultant. Consultant certifies that it fully complies with all requirements and restrictions of state and federal law respecting the employment of undocumented aliens, including, but not limited to, the Immigration Reform and Control Act of 1986, as may be amended from time to time and shall require all subconsultants and sub-subconsultants to comply with the same. Consultant certifies that it has not committed a violation of any such law within the five (5) years immediately preceding the date of execution of this Agreement, and shall not violate any such law at any time during the term of the Agreement.

3.3.10.3 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subconsultant, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination. Consultant shall also comply with all relevant provisions of City's Minority Business Enterprise program, Affirmative Action Plan or other related programs or guidelines currently in effect or hereinafter enacted.

3.3.10.4 Air Quality. To the extent applicable, Consultant must fully comply with all applicable laws, rules and regulations in furnishing or using equipment and/or providing services, including, but not limited to, emissions limits and permitting requirements imposed by the South Coast Air Quality Management District (SCAQMD) and/or California Air Resources Board (CARB). Consultant shall indemnify City against any fines or penalties imposed by SCAQMD, CARB, or any other governmental or regulatory agency for violations of applicable laws, rules and/or regulations by Consultant, its subconsultants, or others for whom Consultant is responsible under its indemnity obligations provided for in this Agreement.

3.3.10.5 Water Quality Management and Compliance. Consultant shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Services including, without limitation, all applicable provisions of the City’s ordinances regulating water quality and storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251, et seq.); the California Porter-Cologne Water Quality Control Act (Water Code § 13000 et seq.); and any and all regulations, policies, or permits issued pursuant to any such authority. Consultant must additionally comply with the lawful requirements of the City, and any other municipality, drainage district, or other local agency with jurisdiction over the location where the Services are to be conducted, regulating water quality and storm water discharges. City may seek damages from Consultant for delay in completing the Services caused by Consultant’s 798
46700.00100\40935195.1
BB&K (2023) -6- PROFESSIONAL SERVICES AGREEMENT
failure to comply with the laws, regulations and policies described in this Section, or any other relevant water quality law, regulation, or policy.

3.3.10.6 Safety. Consultant shall execute and maintain its work so as to avoid injury or damage to any person or property. In carrying out its Services, the Consultant shall at all times be in compliance with all applicable local, state and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of employees appropriate to the nature of the work and the conditions under which the work is to be performed.

3.3.11 Insurance.

3.3.11.1 Time for Compliance. Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurance required under this section. Failure to provide and maintain all required insurance shall be grounds for the City to terminate this Agreement for cause.

3.3.11.2 Types of Insurance Required. As a condition precedent to the effectiveness of this Agreement for work to be performed hereunder, and without limiting the indemnity provisions of the Agreement, the Consultant, in partial performance of its obligations under such Agreement, shall procure and maintain in full force and effect during the term of the Agreement the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Consultant agrees to amend, supplement or endorse the policies to do so.
(A) Commercial General Liability: Commercial General Liability Insurance which affords coverage at least as broad as Insurance Services Office "occurrence" form CG 00 01, or the exact equivalent, with limits of not less than $2,000,000 per occurrence and no less than $4,000,000 in the general aggregate. Defense costs shall be paid in addition to the limits. The policy shall contain no endorsements or provisions (1) limiting coverage for contractual liability; (2) excluding coverage for claims or suits by one insured against another (cross-liability); (3) products/completed operations liability; or (4) containing any other exclusion(s) contrary to the terms or purposes of this Agreement. (B) Automobile Liability Insurance: Automobile Liability Insurance with coverage at least as broad as Insurance Services Office Form CA 00 01 covering "Any Auto" (Symbol 1), or the exact equivalent, covering bodily injury and property damage for all activities with limits of not less than $2,000,000 combined limit for each occurrence. (C) Workers' Compensation: Workers' Compensation
Insurance, as required by the State of California and Employer's Liability Insurance with a limit of not less than $1,000,000 per accident for bodily injury and disease. (D) Professional Liability (Errors & Omissions): Professional Liability insurance or Errors & Omissions insurance appropriate to Consultant’s profession with limits of not less than $2,000,000. Covered professional services shall specifically include all work to be performed under the Agreement and delete any exclusions that may potentially affect the work to be performed (for example, any exclusions relating to lead, asbestos, pollution, testing, underground storage tanks, laboratory analysis, soil work, etc.). If coverage is written on 799
46700.00100\40935195.1
BB&K (2023) -7- PROFESSIONAL SERVICES AGREEMENT
a claims-made basis, the retroactive date shall precede the effective date of the initial Agreement and continuous coverage will be maintained or an extended reporting period will be exercised for a period of at least five (5) years from termination or expiration of this Agreement.

3.3.11.3 Insurance Endorsements. Required insurance policies shall contain the following provisions, or Consultant shall provide endorsements on forms approved by the City to add the following provisions to the insurance policies:
(A) Commercial General Liability: (1) Additional Insured: The City, its officials, officers, employees, agents, and volunteers shall be additional insureds with regard to liability and defense of suits or claims arising out of the performance of the Agreement.

Additional Insured Endorsements shall not (1) be restricted to "ongoing operations"; (2) exclude "contractual liability"; (3) restrict coverage to "sole" liability of Consultant; or (4) contain any other exclusions contrary to the terms or purposes of this Agreement. For all policies of Commercial General Liability insurance, Consultant shall provide endorsements in the form of ISO CG 20 10 10 01 and 20 37 10 01 (or endorsements providing the exact same coverage) to effectuate this requirement. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (B) Automobile Liability: (1) Additional Insured: The City, its directors, officials, officers, employees, agents, and volunteers shall be covered as additional insureds with respect to the ownership, operation, maintenance, use, loading or unloading of any auto owned, leased, hired or borrowed by the Vendor or for which the Vendor is responsible. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium.
(C) Professional Liability (Errors & Omissions): 1) Cancellation:

Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) This insurance shall be written on a policy form coverage specifically designed to protect against acts, errors or omissions of the Consultant. “Covered Professional Services” as designated in the policy must specifically include work performed under this Agreement. The policy must “pay on behalf of” the insured and include a provision establishing the insurer’s duty to defend.
(D) Workers' Compensation: (1) Cancellation: Required
insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) Waiver of Subrogation: A waiver of subrogation stating that the insurer waives all rights of subrogation against the City, its officials, officers, employees, agents, and volunteers.

3.3.11.4 Primary and Non-Contributing Insurance. All policies of Commercial General Liability and Automobile Liability insurance shall be primary and any other insurance, deductible, or self-insurance maintained by the City, its officials, officers, employees, agents, or volunteers shall not contribute with this primary insurance. Policies shall contain or be endorsed to contain such provisions.
800
46700.00100\40935195.1
BB&K (2023) -8- PROFESSIONAL SERVICES AGREEMENT

3.3.11.5 Waiver of Subrogation. All required insurance coverages, except for the professional liability coverage, shall contain or be endorsed to waiver of subrogation in favor of the City, its officials, officers, employees, agents, and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these specifications to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants.

3.3.11.6 Deductibles and Self-Insured Retentions. Any deductible or selfinsured retention must be approved in writing by the City and shall protect the City, its officials, officers, employees, agents, and volunteers in the same manner and to the same extent as they would have been protected had the policy or policies not contained a deductible or self-insured retention.

3.3.11.7 Evidence of Insurance. The Consultant, concurrently with the execution of the Agreement, and as a condition precedent to the effectiveness thereof, shall deliver either certified copies of the required policies, or original certificates on forms approved by the City, together with all endorsements affecting each policy. Required insurance policies shall not be in compliance if they include any limiting provision or endorsement that has not been submitted to the City for approval. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf. At least fifteen (15 days) prior to the expiration of any such policy, evidence of insurance showing that such insurance coverage has been renewed or extended shall be filed with the City. If such coverage is cancelled or reduced and not replaced immediately so as to avoid a lapse in the required coverage, Consultant shall, within ten (10) days after receipt of written notice of such cancellation or reduction of coverage, file with the City evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies.

3.3.11.8 Acceptability of Insurers. Each such policy shall be from a company or companies with a current A.M. Best's rating of no less than A:VII and authorized to transact business of insurance in the State of California, or otherwise allowed to place insurance through surplus line brokers under applicable provisions of the California Insurance Code or any federal law.

3.3.11.9 Enforcement of Agreement Provisions (non estoppel).

Consultant acknowledges and agrees that actual or alleged failure on the part of the City to inform Consultant of non-compliance with any requirement imposes no additional obligation on the City nor does it waive any rights hereunder.

3.3.11.10 Requirements Not Limiting. Requirement of specific coverage or minimum limits contained in this Section are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance.

3.3.11.11 Additional Insurance Provisions
(A) The foregoing requirements as to the types and limits of insurance coverage to be maintained by Consultant, and any approval of said insurance by the City, is not intended to and shall not in any manner limit or qualify the liabilities and obligations 801
46700.00100\40935195.1
BB&K (2023) -9- PROFESSIONAL SERVICES AGREEMENT
otherwise assumed by the Consultant pursuant to this Agreement, including but not limited to, the provisions concerning indemnification.
(B) If at any time during the life of the Agreement, any policy of insurance required under this Agreement does not comply with these specifications or is canceled and not replaced, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Consultant or City will withhold amounts sufficient to pay premium from Consultant payments. In the alternative, City may cancel this Agreement.
(C) The City may require the Consultant to provide complete copies of all insurance policies in effect for the duration of the Project. (D) Neither the City nor any of its officials, officers, employees, agents or volunteers shall be personally responsible for any liability arising under or by virtue of this Agreement.
(E) The limits set forth herein shall apply separately to each insured against whom claims are made or suits are brought, except with respect to the limits of liability. Further the limits set forth herein shall not be construed to relieve the Consultant from liability in excess of such coverage, nor shall it limit the Consultant’s indemnification obligations to the City and shall not preclude the City from taking such other actions available to the City under other provisions of the Agreement or law.
(F) Consultant shall report to the City, in addition to Consultant’s insurer, any and all insurance claims submitted by Consultant in connection with the Services under this Agreement.

3.3.11.12 Insurance for Subconsultants. Consultant shall include all subconsultants engaged in any work for Consultant relating to this Agreement as additional insureds under the Consultant's policies, or the Consultant shall be responsible for causing subconsultants to purchase the appropriate insurance in compliance with the terms of these Insurance Requirements, including adding the City, its officials, officers, employees, agents, and volunteers as additional insureds to the subconsultant's policies. All policies of Commercial General Liability insurance provided by Consultant’s subconsultants performing work relating to this Agreement shall be endorsed to name the City, its officials, officers, employees, agents and volunteers as additional insureds using endorsement form ISO CG 20 38 04 13 or an endorsement providing equivalent coverage. Consultant shall not allow any subconsultant to commence work on any subcontract relating to this Agreement until it has received satisfactory evidence of subconsultant’s compliance with all insurance requirements under this Agreement, to the extent applicable. The Consultant shall provide satisfactory evidence of compliance with this section upon request of the City.

3.4 Labor Code Requirements.

3.4.1 Prevailing Wages. Consultant is aware of the requirements of California Labor Code Section 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., ("Prevailing Wage Laws"), which require the payment of prevailing wage rates and the performance of other requirements on "public works" and "maintenance" projects. If the Services are being performed as part of an applicable "public works" or 802
46700.00100\40935195.1
BB&K (2023) -10- PROFESSIONAL SERVICES AGREEMENT
"maintenance" project, as defined by the Prevailing Wage Laws, and if the total compensation is $1,000 or more, Consultant agrees to fully comply with such Prevailing Wage Laws. City shall provide Consultant with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Consultant shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services available to interested parties upon request, and shall post copies at the Consultant's principal place of business and at the project site. It is the intent of the parties to effectuate the requirements of sections 1771, 1774, 1775, 1776, 1777.5, 1813, and 1815 of the Labor Code within this Agreement, and Consultant shall therefore comply with such Labor Code sections to the fullest extent required by law. Consultant shall defend, indemnify and hold the City, its officials, officers, employees, agents, and volunteers free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws.

3.4.2 Registration/DIR Compliance. If the Services are being performed on a public works project of over $25,000 when the project is for construction, alteration, demolition, installation, or repair work, or a public works project of over $15,000 when the project is for maintenance work, in addition to the foregoing, then pursuant to Labor Code sections 1725.5 and 1771.1, the Consultant and all subconsultants must be registered with the Department of Industrial Relations (“DIR”). Consultant shall maintain registration for the duration of the Project and require the same of any subconsultants.

3.4.3 Compliance Monitoring. This Project may also be subject to compliance monitoring and enforcement by the DIR. It shall be Consultant’s sole responsibility to comply with all applicable registration and labor compliance requirements, including the submission of payroll records directly to the DIR. Any stop orders issued by the DIR against Consultant or any subconsultant that affect Consultant’s performance of services, including any delay, shall be Consultant’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Consultant caused delay and shall not be compensable by the City. Consultant shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the DIR against Consultant or any subconsultant.

3.4.4 Labor Certification. By its signature hereunder, Consultant certifies that it is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker's Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services.

3.5 Termination of Agreement.

3.5.1.1 Grounds for Termination. City may, by written notice to Consultant, terminate the whole or any part of this Agreement at any time and without cause by giving written notice to Consultant of such termination, and specifying the effective date thereof, at least seven (7) days before the effective date of such termination. Upon termination, Consultant shall be compensated only for those Services which have been adequately rendered to City, and Consultant shall be entitled to no further compensation. Consultant may not terminate this Agreement except for cause. The rights and remedies of the City provided in this section shall not be exclusive and are in addition to any other rights and remedies provided by law, equity or under this Agreement.
803
46700.00100\40935195.1
BB&K (2023) -11- PROFESSIONAL SERVICES AGREEMENT

3.5.1.2 Effect of Termination. If this Agreement is terminated as provided herein, City may require Consultant to provide all finished or unfinished Documents and Data and other information of any kind prepared by Consultant in connection with the performance of Services under this Agreement. Consultant shall be required to provide such document and other information within fifteen (15) days of the request.

3.5.1.3 Additional Services. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated.

3.6 Indemnification.

3.6.1 To the fullest extent permitted by law, Consultant shall defend (with counsel of City’s choosing), indemnify and hold the City, its officials, officers, employees, volunteers, and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Consultant, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Consultant’s Services, the Project or this Agreement, including without limitation the payment of all damages, expert witness fees and attorney’s fees and other related costs and expenses except such loss or damage caused by the sole negligence or willful misconduct of the City. Consultant's obligation to indemnify shall survive expiration or termination of this Agreement and shall not be restricted to insurance proceeds, if any, received by Consultant, the City, its officials, officers, employees, agents, or volunteers.

3.6.2 If Consultant’s obligation to defend, indemnify, and/or hold harmless arises out of Consultant’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Consultant’s indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Consultant, and, upon Consultant obtaining a final adjudication by a court of competent jurisdiction, Consultant’s liability for such claim, including the cost to defend, shall not exceed the Consultant’s proportionate percentage of fault.

3.7 General Provisions.

3.7.1 Accounting Records. Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to this Agreement. Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement.

3.7.2 Independent Contractors and Subcontracting.

3.7.2.1 Use of Consultants. Consultant is aware of statutory and case law regarding classification of workers as independent contractors, including California Labor Code Section 2750.3 and Dynamex Operations West, Inc. v. Superior Court, 4 Cal. 5th 903 804
46700.00100\40935195.1
BB&K (2023) -12- PROFESSIONAL SERVICES AGREEMENT
(2018). To ensure that Consultant is in compliance with the California Labor Code, Consultant shall only utilize its employees to provide the Services. Consultant may not provide the services through any independent contractor, subcontractor or subconsultant (“Subcontractor(s)”) unless approved by the City as set forth in Section 3.7.2.2 below. Consultant represents and warrants that all personnel who perform the Services on Consultant’s behalf are Consultant’s employees, and that Consultant complies with all applicable laws, rules and regulations governing its employees, including, but not limited to, the California Labor Code, Unemployment Insurance Code and all applicable Industrial Welfare Commission Wage Orders.

3.7.2.2 Prior Approval Required. Consultant shall not use any Subcontractor to provide the Services, or any portion of the work required by this Agreement, without prior written approval of City. In the event that City authorizes Consultant to use a Subcontractor, Consultant shall enter into a written agreement with the Subcontractor, which must include all provisions of the Agreement, including a restriction on the Subcontractor’s use of further independent contractors, subcontractors or subconsultants without the City’s prior written consent.

3.7.3 Delivery of Notices. All notices permitted or required under this Agreement shall be given to the respective parties at the following address, or at such other address as the respective parties may provide in writing for this purpose:

Consultant: Enterprise Solutions, Inc.
5201 Great American Parkway, Suite 320
Santa Clara, CA 95054
ATTN: Sudesh Verma, Senior Proposal Manager
City: City of Ontario
303 East “B” Street
Ontario, CA 91764
ATTN: Angela Lopez, Executive Director Human
Resources/Risk Management
Such notice shall be deemed made when personally delivered or when mailed, forty-eight (48) hours after deposit in the U.S. Mail, first class postage prepaid and addressed to the party at its applicable address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.

3.7.4 Ownership of Materials and Confidentiality.

3.7.4.1 Documents & Data; Licensing of Intellectual Property. This Agreement creates a non-exclusive and perpetual license for City to copy, use, modify, reuse, or sublicense any and all copyrights, designs, and other intellectual property embodied in plans, specifications, studies, drawings, estimates, and other documents or works of authorship fixed in any tangible medium of expression, including but not limited to, physical drawings or data magnetically or otherwise recorded on computer diskettes, which are prepared or caused to be prepared by Consultant under this Agreement ("Documents & Data"). All Documents & Data shall be and remain the property of City, and shall not be used in whole or in substantial part by Consultant on other projects without the City’s express written permission. Within thirty (30) days following the completion, suspension, abandonment or termination of this Agreement, Consultant shall provide to City reproducible copies of all Documents & Data, in a form and amount required 805
46700.00100\40935195.1
BB&K (2023) -13- PROFESSIONAL SERVICES AGREEMENT
by City. City reserves the right to select the method of document reproduction and to establish where the reproduction will be accomplished. The reproduction expense shall be borne by City at the actual cost of duplication. In the event of a dispute regarding the amount of compensation to which the Consultant is entitled under the termination provisions of this Agreement, Consultant shall provide all Documents & Data to City upon payment of the undisputed amount. Consultant shall have no right to retain or fail to provide to City any such documents pending resolution of the dispute. In addition, Consultant shall retain copies of all Documents & Data on file for a minimum of fifteen (15) years following completion of the Project, and shall make copies available to City upon the payment of actual reasonable duplication costs. Before destroying the Documents & Data following this retention period, Consultant shall make a reasonable effort to notify City and provide City with the opportunity to obtain the documents.

3.7.4.2 Subconsultants. Consultant shall require all subconsultants to agree in writing that City is granted a non-exclusive and perpetual license for any Documents & Data the subconsultant prepares under this Agreement. Consultant represents and warrants that Consultant has the legal right to license any and all Documents & Data. Consultant makes no such representation and warranty in regard to Documents & Data which were prepared by design professionals other than Consultant or its subconsultants, or those provided to Consultant by the City.

3.7.4.3 Right to Use. City shall not be limited in any way in its use or reuse of the Documents and Data or any part of them at any time for purposes of this Project or another project, provided that any such use not within the purposes intended by this Agreement or on a project other than this Project without employing the services of Consultant shall be at City’s sole risk. If City uses or reuses the Documents & Data on any project other than this Project, it shall remove the Consultant’s seal from the Documents & Data and indemnify and hold harmless Consultant and its officers, directors, agents and employees from claims arising out of the negligent use or re-use of the Documents & Data on such other project. Consultant shall be responsible and liable for its Documents & Data, pursuant to the terms of this Agreement, only with respect to the condition of the Documents & Data at the time they are provided to the City upon completion, suspension, abandonment or termination. Consultant shall not be responsible or liable for any revisions to the Documents & Data made by any party other than Consultant, a party for whom the Consultant is legally responsible or liable, or anyone approved by the Consultant.

3.7.4.4 Indemnification. Consultant shall defend, indemnify and hold the City, its directors, officials, officers, employees, volunteers and agents free and harmless, pursuant to the indemnification provisions of this Agreement, for any alleged infringement of any patent, copyright, trade secret, trade name, trademark, or any other proprietary right of any person or entity in consequence of the use on the Project by City of the Documents & Data, including any method, process, product, or concept specified or depicted.

3.7.4.5 Confidentiality. All ideas, memoranda, specifications, plans, procedures, drawings, descriptions, computer program data, input record data, written information, and other Documents & Data either created by or provided to Consultant in connection with the performance of this Agreement shall be held confidential by Consultant. Such materials shall not, without the prior written consent of City, be used by Consultant for any purposes other than the performance of the Services. Nor shall such materials be disclosed to any person or entity not connected with the performance of the Services or the Project. Nothing furnished to Consultant which is otherwise known to Consultant or is generally known, or has 806
46700.00100\40935195.1
BB&K (2023) -14- PROFESSIONAL SERVICES AGREEMENT
become known, to the related industry shall be deemed confidential. Consultant shall not use City's name or insignia, photographs of the Project, or any publicity pertaining to the Services or the Project in any magazine, trade paper, newspaper, television or radio production or other similar medium without the prior written consent of City.

3.7.4.6 Confidential Information. The City shall refrain from releasing Consultant’s proprietary information ("Proprietary Information") unless the City's legal counsel determines that the release of the Proprietary Information is required by the California Public Records Act or other applicable state or federal law, or order of a court of competent jurisdiction, in which case the City shall notify Consultant of its intention to release Proprietary Information.

Consultant shall have five (5) working days after receipt of the release notice to give City written notice of Consultant's objection to the City's release of Proprietary Information. Consultant shall indemnify, defend and hold harmless the City, and its officers, directors, employees, and agents from and against all liability, loss, cost or expense (including attorney’s fees) arising out of a legal action brought to compel the release of Proprietary Information. City shall not release the Proprietary Information after receipt of an objection notice unless either: (1) Consultant fails to fully indemnify, defend (with City's choice of legal counsel), and hold City harmless from any legal action brought to compel such release; and/or (2) a final and non-appealable order by a court of competent jurisdiction requires that City release such information.

3.7.5 Cooperation; Further Acts. The Parties shall fully cooperate with one another, and shall take any additional acts or sign any additional documents as may be necessary, appropriate or convenient to attain the purposes of this Agreement.

3.7.6 Entire Agreement. This Agreement contains the entire agreement of the Parties with respect to the subject matter hereof, and supersedes all prior negotiations, understandings or agreements.

3.7.7 Attorneys’ Fees. If either party commences an action against the other party, either legal, administrative or otherwise, arising out of or in connection with this Agreement, the prevailing party in such litigation shall be entitled to have and recover from the losing party reasonable attorneys’ fees and all costs of such action.

3.7.8 Governing Law. This Agreement shall be governed by the laws of the State of California. Venue shall be in San Bernardino County. In addition to any and all contract requirements pertaining to notices of and requests for compensation or payment for extra work, disputed work, claims and/or changed conditions, Consultant must comply with the claim procedures set forth in Government Code sections 900 et seq. prior to filing any lawsuit against the City. Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to extra work, disputed work, claims, and/or changed conditions have been followed by Consultant. If no such Government Code claim is submitted, or if any prerequisite contractual requirements are not otherwise satisfied as specified herein, Consultant shall be barred from bringing and maintaining a valid lawsuit against the City.

3.7.9 Time of Essence. Time is of the essence for each and every provision of this Agreement.

3.7.10 City's Right to Employ Other Consultants. City reserves right to employ other consultants in connection with this Project.
807
46700.00100\40935195.1
BB&K (2023) -15- PROFESSIONAL SERVICES AGREEMENT

3.7.11 Successors and Assigns. This Agreement shall be binding on the successors and assigns of the parties.

3.7.12 Assignment or Transfer. Consultant shall not assign, sublet, or transfer this Agreement or any rights under or interest in this Agreement without the written consent of the City, which may be withheld for any reason. Any attempt to so assign or so transfer without such consent shall be void and without legal effect and shall constitute grounds for termination.

Consultant shall not subcontract any portion of the Services required by this Agreement, except as expressly stated herein, without prior written approval of City. Subcontracts, if any, shall contain a provision making them subject to all provisions stipulated in this Agreement.

3.7.13 Construction; References; Captions. Since the Parties or their agents have participated fully in the preparation of this Agreement, the language of this Agreement shall be construed simply, according to its fair meaning, and not strictly for or against any Party. Any term referencing time, days or period for performance shall be deemed calendar days and not work days. All references to Consultant include all personnel, employees, agents, and subconsultants of Consultant, except as otherwise specified in this Agreement. All references to City include its elected officials, officers, employees, agents, and volunteers except as otherwise specified in this Agreement. The captions of the various articles and paragraphs are for convenience and ease of reference only, and do not define, limit, augment, or describe the scope, content, or intent of this Agreement.

3.7.14 Amendment; Modification. No supplement, modification, or amendment of this Agreement shall be binding unless executed in writing and signed by both Parties.

3.7.15 Waiver. No waiver of any default shall constitute a waiver of any other default or breach, whether of the same or other covenant or condition. No waiver, benefit, privilege, or service voluntarily given or performed by a Party shall give the other Party any contractual rights by custom, estoppel, or otherwise.

3.7.16 No Third-Party Beneficiaries. There are no intended third party beneficiaries of any right or obligation assumed by the Parties.

3.7.17 Invalidity; Severability. If any portion of this Agreement is declared invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect.

3.7.18 Prohibited Interests. Consultant maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Consultant, to solicit or secure this Agreement. Consultant warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. Consultant further agrees to file, or shall cause its employees or subconsultants to file, a Statement of Economic Interest with the City’s Filing Officer as required under state law in the performance of the Services. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability. For the term of this Agreement, no member, officer or employee of City, during the term of his or her service with City, shall have any direct interest in this Agreement, or obtain any present or anticipated material benefit arising therefrom. 808
46700.00100\40935195.1
BB&K (2023) -16- PROFESSIONAL SERVICES AGREEMENT

3.7.19 Authority to Enter Agreement. Consultant has all requisite power and authority to conduct its business and to execute, deliver, and perform the Agreement. Each Party warrants that the individuals who have signed this Agreement have the legal power, right, and authority to make this Agreement and bind each respective Party.

3.7.20 Counterparts. This Agreement may be signed in counterparts, each of which shall constitute an original.

3.7.21 Survival. All rights and obligations hereunder that by their nature are to continue after any expiration or termination of this Agreement, including, but not limited to, the indemnification obligations, shall survive any such expiration or termination.

SIGNATURES ON NEXT PAGE
809
46700.00100\40935195.1
BB&K (2023) -17- PROFESSIONAL SERVICES AGREEMENT

SIGNATURE PAGE TO PROFESSIONAL SERVICES AGREEMENT

BETWEEN THE CITY OF ONTARIO AND
Enterprise Solutions, Inc.

IN WITNESS WHEREOF, each of the Parties has caused this Agreement to be executed on the day and year first above written.

CITY OF ONTARIO Enterprise Solutions, Inc.

By: AAA
Its: BBB
Printed Name: CCC
By: DDD
Its: EEE
Printed Name: FFF
[If Corporation, TWO SIGNATURES,
President OR Vice President AND Secretary
OR Treasurer REQUIRED]
Approved By:

Scott Ochoa
City Manager
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:

City Clerk
810
46700.00100\40935195.1
BB&K (2023) Exhibit “A”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "A"

SCOPE OF SERVICES

PROPOSED SCOPE OF SERVICES
811
46700.00100\40935195.1
BB&K (2023) Exhibit “B”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "B"

SCHEDULE OF SERVICES
812
46700.00100\40935195.1
BB&K (2023) Exhibit “C”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "C"

COMPENSATION
813
46700.00100\40935195.1
BB&K (2023) Exhibit “C”-1 PROFESSIONAL SERVICES AGREEMENT

CITY OF ONTARIO

PROFESSIONAL SERVICES AGREEMENT

1. PARTIES AND DATE.

This Agreement is made and entered as of ____________, by and between the City of Ontario, a municipal corporation organized under the laws of the State of California with its principal place of business at 303 East “B” Street, Ontario, California 91764-4196, County of San Bernardino, State of California ("City") and Resource Logistics, Inc., a Corporation, with its principal place of business at 39 Milltown Road, East Brunswick, NJ 08816 are sometimes individually referred to herein as "Party" and collectively as "Parties."

2. RECITALS.

2.1 Consultant.

Consultant desires to perform and assume responsibility for the provision of certain professional services required by the City on the terms and conditions set forth in this Agreement.

Consultant represents that it is experienced in providing temporary staffing services to public clients, is licensed in the State of California, and is familiar with the plans of City.

2.2 Project.

City desires to engage Consultant to render such professional services for temporary staffing services for the City on an as-needed basis (“Project”) as set forth in this Agreement.

3. TERMS.

3.1 Scope of Services and Term.

3.1.1 General Scope of Services. Consultant promises and agrees to furnish to the City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the professional temporary staffing consulting services necessary for the Project ("Services"). The Services are more particularly described in Exhibit "A" attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordance with, this Agreement, the exhibits attached hereto and incorporated herein by reference, and all applicable local, state and federal laws, rules and regulations.

PAUL S. LEON
MAYOR

DEBRA PORADA

MAYOR PRO TEM
ALAN D. WAPNER
JIM W. BOWMAN

RUBEN VALENCIA

COUNCIL MEMBERS

SHEILA MAUTZ

CITY CLERK
JAMES R. MILHISER

TREASURER

SCOTT OCHOA

CITY MANAGER
814
46700.00100\40935195.1
BB&K (2023) -2- PROFESSIONAL SERVICES AGREEMENT

3.1.2 Term. The term of this Agreement shall be from November 21, 2023 to November 21, 2026, unless earlier terminated as provided herein. The City shall have the unilateral option, at its sole discretion, to renew this Agreement automatically for no more than two (2) additional one-year terms, unless earlier terminated as provided herein. Consultant shall complete the Services within the term of this Agreement and shall meet any other established schedules and deadlines. The Parties may, by mutual, written consent, extend the term of this Agreement if necessary to complete the Services.

3.2 Compensation.

3.2.1 Compensation. Consultant shall receive compensation, including authorized reimbursements, for all Services rendered under this Agreement at the rates set forth in Exhibit "C" attached hereto and incorporated herein by reference. The total compensation shall not exceed Seven Hundred Thousand Dollars and Zero Cents ($700,000) without written approval of the City Council or City Manager, as applicable. Extra Work may be authorized, as described below, and if authorized, will be compensated at the rates and manner set forth in this Agreement.

3.2.2 Payment of Compensation. Consultant shall submit to City a monthly invoice which indicates work completed and hours of Services rendered by Consultant. The invoice shall describe the amount of Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the invoice.

City shall, within 30 days of receiving such invoice, review the invoice and pay all non-disputed and approved charges. If the City disputes any of Consultant's fees, the City shall give written notice to Consultant within thirty (30) days of receipt of an invoice of any disputed fees set forth therein. Payment shall not constitute acceptance of any Services completed by Consultant. The making of final payment shall not constitute a waiver of any claims by the City for any reason whatsoever.

3.2.3 Reimbursement for Expenses. Consultant shall not be reimbursed for any expenses unless authorized in writing by City, or included in Exhibit "C" of this Agreement.

3.2.4 Extra Work. At any time during the term of this Agreement, City may request that Consultant perform Extra Work. As used herein, "Extra Work" means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement.

Consultant shall not perform, nor be compensated for, Extra Work without written authorization from the City.

3.3 Responsibilities of Consultant.

3.3.1 Independent Contractor; Control and Payment of Subordinates. The Services shall be performed by Consultant or under its supervision. Consultant will determine the means, methods and details of performing the Services subject to the requirements of this Agreement. City retains Consultant on an independent contractor basis and not as an employee.

Any personnel performing the Services on behalf of Consultant shall not be employees of City and shall at all times be under Consultant's exclusive direction and control. Neither City, or any of its officials, officers, directors, employees or agents shall have control over the conduct of Consultant or any of Consultants officers, employees or agents, except as set forth in this Agreement. Consultant shall pay all wages, salaries, and other amounts due such personnel in 815
46700.00100\40935195.1
BB&K (2023) -3- PROFESSIONAL SERVICES AGREEMENT
connection with their performance of Services under this Agreement and as required by law.

Consultant shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers' compensation insurance.

3.3.2 Schedule of Services. Consultant shall perform the Services in a prompt and timely manner and in accordance with the Schedule of Services set forth in Exhibit "B" attached hereto and incorporated herein by reference. Consultant represents that it has the professional and technical personnel required to perform the Services expeditiously. Upon request of City, Consultant shall provide a more detailed schedule of anticipated performance to meet the Schedule of Services.

3.3.3 Conformance to Applicable Requirements. All work prepared by Consultant shall be subject to the approval of City.

3.3.4 Substitution of Key Personnel. Consultant has represented to City that certain key personnel will perform and coordinate the Services under this Agreement. Should one or more of such personnel become unavailable, Consultant may substitute other personnel of at least equal competence upon written approval of City. In the event that City and Consultant cannot agree as to the substitution of key personnel, City shall be entitled to terminate this Agreement for cause. The key personnel for performance of this Agreement are as follows:

Deepak Arora, COO/Director.

3.3.5 City's Representative. The City hereby designates Angela Lopez, Executive Director Human Resources/Risk Management, or his/her designee, to act as its representative in all matters pertaining to the administration and performance of this Agreement ("City's Representative"). City's Representative shall have the power to act on behalf of the City for review and approval of all products submitted by Consultant but not the authority to enlarge the Scope of Services or change the total compensation due to Consultant under this Agreement.

The City Manager shall be authorized to act on City's behalf and to execute all necessary documents which enlarge the Scope of Services or change the Consultant's total compensation subject to the provisions contained in this Agreement. Consultant shall not accept direction or orders from any person other than the City Manager, City's Representative or his/her designee.

3.3.6 Consultant's Representative. Consultant hereby designates Deepak Arora, COO/Director, or his/her designee, to act as its representative for the performance of this Agreement ("Consultant's Representative"). Consultant's Representative shall have full authority to represent and act on behalf of the Consultant for all purposes under this Agreement. The Consultant's Representative shall supervise and direct the Services, using his/her best skill and attention, and shall be responsible for all means, methods, techniques, sequences, and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.

3.3.7 Coordination of Services. Consultant agrees to work closely with City staff in the performance of Services and shall be available to City's staff, consultants and other staff at all reasonable times.

3.3.8 Standard of Care; Performance of Employees. Consultant shall perform all Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals in the same discipline in the State of 816
46700.00100\40935195.1
BB&K (2023) -4- PROFESSIONAL SERVICES AGREEMENT
California. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services. Consultant warrants that all employees and subconsultants shall have sufficient skill and experience to perform the Services assigned to them. Consultant represents that it, its employees and subconsultants have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services, and that such licenses and approvals shall be maintained throughout the term of this Agreement. Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant's failure to comply with the standard of care provided for herein. Any employee of the Consultant or its subconsultants who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed from the Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.

3.3.9 Period of Performance.

3.3.9.1 Consultant shall perform and complete all Services under this Agreement within the term set forth in Section 3.1.2 above (“Performance Time”). Consultant shall also perform the Services in strict accordance with any completion schedule or Project milestones described in Exhibits “A” or “B” attached hereto, or which may be separately agreed upon in writing by the City and Consultant (“Performance Milestones”). Consultant agrees that if the Services are not completed within the aforementioned Performance Time and/or pursuant to any such Performance Milestones developed pursuant to provisions of this Agreement, it is understood, acknowledged and agreed that the City will suffer damage.

3.3.9.2 Neither City nor Consultant shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the non-performing Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Consultant and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the services and Agreement.

3.3.9.3 Should a Force Majeure Event occur, the non-performing Party shall, within a reasonable time of being prevented from performing, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events and/or delays, regardless of the Party responsible for the delay, shall not entitle Consultant to any additional compensation.

Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement. 817
46700.00100\40935195.1
BB&K (2023) -5- PROFESSIONAL SERVICES AGREEMENT

3.3.10 Laws and Regulations; Employee/Labor Certification.

3.3.10.1 Compliance with Laws. Consultant shall keep itself fully informed of and in compliance with all local, state and federal laws, rules and regulations in any manner affecting the performance of the Project or the Services, including all Cal/OSHA requirements, and shall give all notices required by law. Consultant shall be liable for all violations of such laws and regulations in connection with the Services and this Agreement. All violations of such laws and regulations shall be grounds for the City to terminate the Agreement for cause.

3.3.10.2 Employment Eligibility; Consultant. Consultant certifies that it fully complies with all requirements and restrictions of state and federal law respecting the employment of undocumented aliens, including, but not limited to, the Immigration Reform and Control Act of 1986, as may be amended from time to time and shall require all subconsultants and sub-subconsultants to comply with the same. Consultant certifies that it has not committed a violation of any such law within the five (5) years immediately preceding the date of execution of this Agreement, and shall not violate any such law at any time during the term of the Agreement.

3.3.10.3 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subconsultant, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination. Consultant shall also comply with all relevant provisions of City's Minority Business Enterprise program, Affirmative Action Plan or other related programs or guidelines currently in effect or hereinafter enacted.

3.3.10.4 Air Quality. To the extent applicable, Consultant must fully comply with all applicable laws, rules and regulations in furnishing or using equipment and/or providing services, including, but not limited to, emissions limits and permitting requirements imposed by the South Coast Air Quality Management District (SCAQMD) and/or California Air Resources Board (CARB). Consultant shall indemnify City against any fines or penalties imposed by SCAQMD, CARB, or any other governmental or regulatory agency for violations of applicable laws, rules and/or regulations by Consultant, its subconsultants, or others for whom Consultant is responsible under its indemnity obligations provided for in this Agreement.

3.3.10.5 Water Quality Management and Compliance. Consultant shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Services including, without limitation, all applicable provisions of the City’s ordinances regulating water quality and storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251, et seq.); the California Porter-Cologne Water Quality Control Act (Water Code § 13000 et seq.); and any and all regulations, policies, or permits issued pursuant to any such authority. Consultant must additionally comply with the lawful requirements of the City, and any other municipality, drainage district, or other local agency with jurisdiction over the location where the Services are to be conducted, regulating water quality and storm water discharges. City may seek damages from Consultant for delay in completing the Services caused by Consultant’s failure to comply with the laws, regulations and policies described in this Section, or any other relevant water quality law, regulation, or policy.
818
46700.00100\40935195.1
BB&K (2023) -6- PROFESSIONAL SERVICES AGREEMENT

3.3.10.6 Safety. Consultant shall execute and maintain its work so as to avoid injury or damage to any person or property. In carrying out its Services, the Consultant shall at all times be in compliance with all applicable local, state and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of employees appropriate to the nature of the work and the conditions under which the work is to be performed.

3.3.11 Insurance.

3.3.11.1 Time for Compliance. Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurance required under this section. Failure to provide and maintain all required insurance shall be grounds for the City to terminate this Agreement for cause.

3.3.11.2 Types of Insurance Required. As a condition precedent to the effectiveness of this Agreement for work to be performed hereunder, and without limiting the indemnity provisions of the Agreement, the Consultant, in partial performance of its obligations under such Agreement, shall procure and maintain in full force and effect during the term of the Agreement the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Consultant agrees to amend, supplement or endorse the policies to do so.
(A) Commercial General Liability: Commercial General Liability Insurance which affords coverage at least as broad as Insurance Services Office "occurrence" form CG 00 01, or the exact equivalent, with limits of not less than $2,000,000 per occurrence and no less than $4,000,000 in the general aggregate. Defense costs shall be paid in addition to the limits. The policy shall contain no endorsements or provisions (1) limiting coverage for contractual liability; (2) excluding coverage for claims or suits by one insured against another (cross-liability); (3) products/completed operations liability; or (4) containing any other exclusion(s) contrary to the terms or purposes of this Agreement. (B) Automobile Liability Insurance: Automobile Liability Insurance with coverage at least as broad as Insurance Services Office Form CA 00 01 covering "Any Auto" (Symbol 1), or the exact equivalent, covering bodily injury and property damage for all activities with limits of not less than $2,000,000 combined limit for each occurrence. (C) Workers' Compensation: Workers' Compensation
Insurance, as required by the State of California and Employer's Liability Insurance with a limit of not less than $1,000,000 per accident for bodily injury and disease. (D) Professional Liability (Errors & Omissions): Professional Liability insurance or Errors & Omissions insurance appropriate to Consultant’s profession with limits of not less than $2,000,000. Covered professional services shall specifically include all work to be performed under the Agreement and delete any exclusions that may potentially affect the work to be performed (for example, any exclusions relating to lead, asbestos, pollution, testing, underground storage tanks, laboratory analysis, soil work, etc.). If coverage is written on a claims-made basis, the retroactive date shall precede the effective date of the initial Agreement and continuous coverage will be maintained or an extended reporting period will be exercised for a period of at least five (5) years from termination or expiration of this Agreement. 819
46700.00100\40935195.1
BB&K (2023) -7- PROFESSIONAL SERVICES AGREEMENT

3.3.11.3 Insurance Endorsements. Required insurance policies shall contain the following provisions, or Consultant shall provide endorsements on forms approved by the City to add the following provisions to the insurance policies:
(A) Commercial General Liability: (1) Additional Insured: The City, its officials, officers, employees, agents, and volunteers shall be additional insureds with regard to liability and defense of suits or claims arising out of the performance of the Agreement.

Additional Insured Endorsements shall not (1) be restricted to "ongoing operations"; (2) exclude "contractual liability"; (3) restrict coverage to "sole" liability of Consultant; or (4) contain any other exclusions contrary to the terms or purposes of this Agreement. For all policies of Commercial General Liability insurance, Consultant shall provide endorsements in the form of ISO CG 20 10 10 01 and 20 37 10 01 (or endorsements providing the exact same coverage) to effectuate this requirement. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (B) Automobile Liability: (1) Additional Insured: The City, its directors, officials, officers, employees, agents, and volunteers shall be covered as additional insureds with respect to the ownership, operation, maintenance, use, loading or unloading of any auto owned, leased, hired or borrowed by the Vendor or for which the Vendor is responsible. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium.
(C) Professional Liability (Errors & Omissions): 1) Cancellation:

Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) This insurance shall be written on a policy form coverage specifically designed to protect against acts, errors or omissions of the Consultant. “Covered Professional Services” as designated in the policy must specifically include work performed under this Agreement. The policy must “pay on behalf of” the insured and include a provision establishing the insurer’s duty to defend.
(D) Workers' Compensation: (1) Cancellation: Required
insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) Waiver of Subrogation: A waiver of subrogation stating that the insurer waives all rights of subrogation against the City, its officials, officers, employees, agents, and volunteers.

3.3.11.4 Primary and Non-Contributing Insurance. All policies of Commercial General Liability and Automobile Liability insurance shall be primary and any other insurance, deductible, or self-insurance maintained by the City, its officials, officers, employees, agents, or volunteers shall not contribute with this primary insurance. Policies shall contain or be endorsed to contain such provisions.

3.3.11.5 Waiver of Subrogation. All required insurance coverages, except for the professional liability coverage, shall contain or be endorsed to waiver of subrogation in favor of the City, its officials, officers, employees, agents, and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these specifications 820
46700.00100\40935195.1
BB&K (2023) -8- PROFESSIONAL SERVICES AGREEMENT
to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants.

3.3.11.6 Deductibles and Self-Insured Retentions. Any deductible or selfinsured retention must be approved in writing by the City and shall protect the City, its officials, officers, employees, agents, and volunteers in the same manner and to the same extent as they would have been protected had the policy or policies not contained a deductible or self-insured retention.

3.3.11.7 Evidence of Insurance. The Consultant, concurrently with the execution of the Agreement, and as a condition precedent to the effectiveness thereof, shall deliver either certified copies of the required policies, or original certificates on forms approved by the City, together with all endorsements affecting each policy. Required insurance policies shall not be in compliance if they include any limiting provision or endorsement that has not been submitted to the City for approval. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf. At least fifteen (15 days) prior to the expiration of any such policy, evidence of insurance showing that such insurance coverage has been renewed or extended shall be filed with the City. If such coverage is cancelled or reduced and not replaced immediately so as to avoid a lapse in the required coverage, Consultant shall, within ten (10) days after receipt of written notice of such cancellation or reduction of coverage, file with the City evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies.

3.3.11.8 Acceptability of Insurers. Each such policy shall be from a company or companies with a current A.M. Best's rating of no less than A:VII and authorized to transact business of insurance in the State of California, or otherwise allowed to place insurance through surplus line brokers under applicable provisions of the California Insurance Code or any federal law.

3.3.11.9 Enforcement of Agreement Provisions (non estoppel).

Consultant acknowledges and agrees that actual or alleged failure on the part of the City to inform Consultant of non-compliance with any requirement imposes no additional obligation on the City nor does it waive any rights hereunder.

3.3.11.10 Requirements Not Limiting. Requirement of specific coverage or minimum limits contained in this Section are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance.

3.3.11.11 Additional Insurance Provisions
(A) The foregoing requirements as to the types and limits of insurance coverage to be maintained by Consultant, and any approval of said insurance by the City, is not intended to and shall not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Consultant pursuant to this Agreement, including but not limited to, the provisions concerning indemnification.
(B) If at any time during the life of the Agreement, any policy of insurance required under this Agreement does not comply with these specifications or is canceled 821
46700.00100\40935195.1
BB&K (2023) -9- PROFESSIONAL SERVICES AGREEMENT
and not replaced, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Consultant or City will withhold amounts sufficient to pay premium from Consultant payments. In the alternative, City may cancel this Agreement.
(C) The City may require the Consultant to provide complete copies of all insurance policies in effect for the duration of the Project. (D) Neither the City nor any of its officials, officers, employees, agents or volunteers shall be personally responsible for any liability arising under or by virtue of this Agreement.
(E) The limits set forth herein shall apply separately to each insured against whom claims are made or suits are brought, except with respect to the limits of liability. Further the limits set forth herein shall not be construed to relieve the Consultant from liability in excess of such coverage, nor shall it limit the Consultant’s indemnification obligations to the City and shall not preclude the City from taking such other actions available to the City under other provisions of the Agreement or law.
(F) Consultant shall report to the City, in addition to Consultant’s insurer, any and all insurance claims submitted by Consultant in connection with the Services under this Agreement.

3.3.11.12 Insurance for Subconsultants. Consultant shall include all subconsultants engaged in any work for Consultant relating to this Agreement as additional insureds under the Consultant's policies, or the Consultant shall be responsible for causing subconsultants to purchase the appropriate insurance in compliance with the terms of these Insurance Requirements, including adding the City, its officials, officers, employees, agents, and volunteers as additional insureds to the subconsultant's policies. All policies of Commercial General Liability insurance provided by Consultant’s subconsultants performing work relating to this Agreement shall be endorsed to name the City, its officials, officers, employees, agents and volunteers as additional insureds using endorsement form ISO CG 20 38 04 13 or an endorsement providing equivalent coverage. Consultant shall not allow any subconsultant to commence work on any subcontract relating to this Agreement until it has received satisfactory evidence of subconsultant’s compliance with all insurance requirements under this Agreement, to the extent applicable. The Consultant shall provide satisfactory evidence of compliance with this section upon request of the City.

3.4 Labor Code Requirements.

3.4.1 Prevailing Wages. Consultant is aware of the requirements of California Labor Code Section 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., ("Prevailing Wage Laws"), which require the payment of prevailing wage rates and the performance of other requirements on "public works" and "maintenance" projects. If the Services are being performed as part of an applicable "public works" or "maintenance" project, as defined by the Prevailing Wage Laws, and if the total compensation is $1,000 or more, Consultant agrees to fully comply with such Prevailing Wage Laws. City shall provide Consultant with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Consultant shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services 822
46700.00100\40935195.1
BB&K (2023) -10- PROFESSIONAL SERVICES AGREEMENT
available to interested parties upon request, and shall post copies at the Consultant's principal place of business and at the project site. It is the intent of the parties to effectuate the requirements of sections 1771, 1774, 1775, 1776, 1777.5, 1813, and 1815 of the Labor Code within this Agreement, and Consultant shall therefore comply with such Labor Code sections to the fullest extent required by law. Consultant shall defend, indemnify and hold the City, its officials, officers, employees, agents, and volunteers free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws.

3.4.2 Registration/DIR Compliance. If the Services are being performed on a public works project of over $25,000 when the project is for construction, alteration, demolition, installation, or repair work, or a public works project of over $15,000 when the project is for maintenance work, in addition to the foregoing, then pursuant to Labor Code sections 1725.5 and 1771.1, the Consultant and all subconsultants must be registered with the Department of Industrial Relations (“DIR”). Consultant shall maintain registration for the duration of the Project and require the same of any subconsultants.

3.4.3 Compliance Monitoring. This Project may also be subject to compliance monitoring and enforcement by the DIR. It shall be Consultant’s sole responsibility to comply with all applicable registration and labor compliance requirements, including the submission of payroll records directly to the DIR. Any stop orders issued by the DIR against Consultant or any subconsultant that affect Consultant’s performance of services, including any delay, shall be Consultant’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Consultant caused delay and shall not be compensable by the City. Consultant shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the DIR against Consultant or any subconsultant.

3.4.4 Labor Certification. By its signature hereunder, Consultant certifies that it is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker's Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services.

3.5 Termination of Agreement.

3.5.1.1 Grounds for Termination. City may, by written notice to Consultant, terminate the whole or any part of this Agreement at any time and without cause by giving written notice to Consultant of such termination, and specifying the effective date thereof, at least seven (7) days before the effective date of such termination. Upon termination, Consultant shall be compensated only for those Services which have been adequately rendered to City, and Consultant shall be entitled to no further compensation. Consultant may not terminate this Agreement except for cause. The rights and remedies of the City provided in this section shall not be exclusive and are in addition to any other rights and remedies provided by law, equity or under this Agreement.

3.5.1.2 Effect of Termination. If this Agreement is terminated as provided herein, City may require Consultant to provide all finished or unfinished Documents and Data and other information of any kind prepared by Consultant in connection with the performance of Services under this Agreement. Consultant shall be required to provide such document and other information within fifteen (15) days of the request. 823
46700.00100\40935195.1
BB&K (2023) -11- PROFESSIONAL SERVICES AGREEMENT

3.5.1.3 Additional Services. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated.

3.6 Indemnification.

3.6.1 To the fullest extent permitted by law, Consultant shall defend (with counsel of City’s choosing), indemnify and hold the City, its officials, officers, employees, volunteers, and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Consultant, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Consultant’s Services, the Project or this Agreement, including without limitation the payment of all damages, expert witness fees and attorney’s fees and other related costs and expenses except such loss or damage caused by the sole negligence or willful misconduct of the City. Consultant's obligation to indemnify shall survive expiration or termination of this Agreement and shall not be restricted to insurance proceeds, if any, received by Consultant, the City, its officials, officers, employees, agents, or volunteers.

3.6.2 If Consultant’s obligation to defend, indemnify, and/or hold harmless arises out of Consultant’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Consultant’s indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Consultant, and, upon Consultant obtaining a final adjudication by a court of competent jurisdiction, Consultant’s liability for such claim, including the cost to defend, shall not exceed the Consultant’s proportionate percentage of fault.

3.7 General Provisions.

3.7.1 Accounting Records. Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to this Agreement. Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement.

3.7.2 Independent Contractors and Subcontracting.

3.7.2.1 Use of Consultants. Consultant is aware of statutory and case law regarding classification of workers as independent contractors, including California Labor Code Section 2750.3 and Dynamex Operations West, Inc. v. Superior Court, 4 Cal. 5th 903 (2018). To ensure that Consultant is in compliance with the California Labor Code, Consultant shall only utilize its employees to provide the Services. Consultant may not provide the services through any independent contractor, subcontractor or subconsultant (“Subcontractor(s)”) unless approved by the City as set forth in Section 3.7.2.2 below. Consultant represents and warrants that all personnel who perform the Services on Consultant’s behalf are Consultant’s employees, and that Consultant complies with all applicable laws, rules and regulations governing its 824
46700.00100\40935195.1
BB&K (2023) -12- PROFESSIONAL SERVICES AGREEMENT
employees, including, but not limited to, the California Labor Code, Unemployment Insurance Code and all applicable Industrial Welfare Commission Wage Orders.

3.7.2.2 Prior Approval Required. Consultant shall not use any Subcontractor to provide the Services, or any portion of the work required by this Agreement, without prior written approval of City. In the event that City authorizes Consultant to use a Subcontractor, Consultant shall enter into a written agreement with the Subcontractor, which must include all provisions of the Agreement, including a restriction on the Subcontractor’s use of further independent contractors, subcontractors or subconsultants without the City’s prior written consent.

3.7.3 Delivery of Notices. All notices permitted or required under this Agreement shall be given to the respective parties at the following address, or at such other address as the respective parties may provide in writing for this purpose:

Consultant: Resource Logistics, Inc.
39 Milltown Road
East Brunswick, NJ 08816
ATTN: Deepak Arora, COO/Director
City: City of Ontario
303 East “B” Street
Ontario, CA 91764
ATTN: Angela Lopez, Executive Director Human
Resources/Risk Management
Such notice shall be deemed made when personally delivered or when mailed, forty-eight (48) hours after deposit in the U.S. Mail, first class postage prepaid and addressed to the party at its applicable address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.

3.7.4 Ownership of Materials and Confidentiality.

3.7.4.1 Documents & Data; Licensing of Intellectual Property. This Agreement creates a non-exclusive and perpetual license for City to copy, use, modify, reuse, or sublicense any and all copyrights, designs, and other intellectual property embodied in plans, specifications, studies, drawings, estimates, and other documents or works of authorship fixed in any tangible medium of expression, including but not limited to, physical drawings or data magnetically or otherwise recorded on computer diskettes, which are prepared or caused to be prepared by Consultant under this Agreement ("Documents & Data"). All Documents & Data shall be and remain the property of City, and shall not be used in whole or in substantial part by Consultant on other projects without the City’s express written permission. Within thirty (30) days following the completion, suspension, abandonment or termination of this Agreement, Consultant shall provide to City reproducible copies of all Documents & Data, in a form and amount required by City. City reserves the right to select the method of document reproduction and to establish where the reproduction will be accomplished. The reproduction expense shall be borne by City at the actual cost of duplication. In the event of a dispute regarding the amount of compensation to which the Consultant is entitled under the termination provisions of this Agreement, Consultant shall provide all Documents & Data to City upon payment of the undisputed amount. Consultant shall have no right to retain or fail to provide to City any such documents pending resolution of 825
46700.00100\40935195.1
BB&K (2023) -13- PROFESSIONAL SERVICES AGREEMENT
the dispute. In addition, Consultant shall retain copies of all Documents & Data on file for a minimum of fifteen (15) years following completion of the Project, and shall make copies available to City upon the payment of actual reasonable duplication costs. Before destroying the Documents & Data following this retention period, Consultant shall make a reasonable effort to notify City and provide City with the opportunity to obtain the documents.

3.7.4.2 Subconsultants. Consultant shall require all subconsultants to agree in writing that City is granted a non-exclusive and perpetual license for any Documents & Data the subconsultant prepares under this Agreement. Consultant represents and warrants that Consultant has the legal right to license any and all Documents & Data. Consultant makes no such representation and warranty in regard to Documents & Data which were prepared by design professionals other than Consultant or its subconsultants, or those provided to Consultant by the City.

3.7.4.3 Right to Use. City shall not be limited in any way in its use or reuse of the Documents and Data or any part of them at any time for purposes of this Project or another project, provided that any such use not within the purposes intended by this Agreement or on a project other than this Project without employing the services of Consultant shall be at City’s sole risk. If City uses or reuses the Documents & Data on any project other than this Project, it shall remove the Consultant’s seal from the Documents & Data and indemnify and hold harmless Consultant and its officers, directors, agents and employees from claims arising out of the negligent use or re-use of the Documents & Data on such other project. Consultant shall be responsible and liable for its Documents & Data, pursuant to the terms of this Agreement, only with respect to the condition of the Documents & Data at the time they are provided to the City upon completion, suspension, abandonment or termination. Consultant shall not be responsible or liable for any revisions to the Documents & Data made by any party other than Consultant, a party for whom the Consultant is legally responsible or liable, or anyone approved by the Consultant.

3.7.4.4 Indemnification. Consultant shall defend, indemnify and hold the City, its directors, officials, officers, employees, volunteers and agents free and harmless, pursuant to the indemnification provisions of this Agreement, for any alleged infringement of any patent, copyright, trade secret, trade name, trademark, or any other proprietary right of any person or entity in consequence of the use on the Project by City of the Documents & Data, including any method, process, product, or concept specified or depicted.

3.7.4.5 Confidentiality. All ideas, memoranda, specifications, plans, procedures, drawings, descriptions, computer program data, input record data, written information, and other Documents & Data either created by or provided to Consultant in connection with the performance of this Agreement shall be held confidential by Consultant. Such materials shall not, without the prior written consent of City, be used by Consultant for any purposes other than the performance of the Services. Nor shall such materials be disclosed to any person or entity not connected with the performance of the Services or the Project. Nothing furnished to Consultant which is otherwise known to Consultant or is generally known, or has become known, to the related industry shall be deemed confidential. Consultant shall not use City's name or insignia, photographs of the Project, or any publicity pertaining to the Services or the Project in any magazine, trade paper, newspaper, television or radio production or other similar medium without the prior written consent of City. 826
46700.00100\40935195.1
BB&K (2023) -14- PROFESSIONAL SERVICES AGREEMENT

3.7.4.6 Confidential Information. The City shall refrain from releasing Consultant’s proprietary information ("Proprietary Information") unless the City's legal counsel determines that the release of the Proprietary Information is required by the California Public Records Act or other applicable state or federal law, or order of a court of competent jurisdiction, in which case the City shall notify Consultant of its intention to release Proprietary Information.

Consultant shall have five (5) working days after receipt of the release notice to give City written notice of Consultant's objection to the City's release of Proprietary Information. Consultant shall indemnify, defend and hold harmless the City, and its officers, directors, employees, and agents from and against all liability, loss, cost or expense (including attorney’s fees) arising out of a legal action brought to compel the release of Proprietary Information. City shall not release the Proprietary Information after receipt of an objection notice unless either: (1) Consultant fails to fully indemnify, defend (with City's choice of legal counsel), and hold City harmless from any legal action brought to compel such release; and/or (2) a final and non-appealable order by a court of competent jurisdiction requires that City release such information.

3.7.5 Cooperation; Further Acts. The Parties shall fully cooperate with one another, and shall take any additional acts or sign any additional documents as may be necessary, appropriate or convenient to attain the purposes of this Agreement.

3.7.6 Entire Agreement. This Agreement contains the entire agreement of the Parties with respect to the subject matter hereof, and supersedes all prior negotiations, understandings or agreements.

3.7.7 Attorneys’ Fees. If either party commences an action against the other party, either legal, administrative or otherwise, arising out of or in connection with this Agreement, the prevailing party in such litigation shall be entitled to have and recover from the losing party reasonable attorneys’ fees and all costs of such action.

3.7.8 Governing Law. This Agreement shall be governed by the laws of the State of California. Venue shall be in San Bernardino County. In addition to any and all contract requirements pertaining to notices of and requests for compensation or payment for extra work, disputed work, claims and/or changed conditions, Consultant must comply with the claim procedures set forth in Government Code sections 900 et seq. prior to filing any lawsuit against the City. Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to extra work, disputed work, claims, and/or changed conditions have been followed by Consultant. If no such Government Code claim is submitted, or if any prerequisite contractual requirements are not otherwise satisfied as specified herein, Consultant shall be barred from bringing and maintaining a valid lawsuit against the City.

3.7.9 Time of Essence. Time is of the essence for each and every provision of this Agreement.

3.7.10 City's Right to Employ Other Consultants. City reserves right to employ other consultants in connection with this Project.

3.7.11 Successors and Assigns. This Agreement shall be binding on the successors and assigns of the parties.

3.7.12 Assignment or Transfer. Consultant shall not assign, sublet, or transfer this 827
46700.00100\40935195.1
BB&K (2023) -15- PROFESSIONAL SERVICES AGREEMENT
Agreement or any rights under or interest in this Agreement without the written consent of the City, which may be withheld for any reason. Any attempt to so assign or so transfer without such consent shall be void and without legal effect and shall constitute grounds for termination.

Consultant shall not subcontract any portion of the Services required by this Agreement, except as expressly stated herein, without prior written approval of City. Subcontracts, if any, shall contain a provision making them subject to all provisions stipulated in this Agreement.

3.7.13 Construction; References; Captions. Since the Parties or their agents have participated fully in the preparation of this Agreement, the language of this Agreement shall be construed simply, according to its fair meaning, and not strictly for or against any Party. Any term referencing time, days or period for performance shall be deemed calendar days and not work days. All references to Consultant include all personnel, employees, agents, and subconsultants of Consultant, except as otherwise specified in this Agreement. All references to City include its elected officials, officers, employees, agents, and volunteers except as otherwise specified in this Agreement. The captions of the various articles and paragraphs are for convenience and ease of reference only, and do not define, limit, augment, or describe the scope, content, or intent of this Agreement.

3.7.14 Amendment; Modification. No supplement, modification, or amendment of this Agreement shall be binding unless executed in writing and signed by both Parties.

3.7.15 Waiver. No waiver of any default shall constitute a waiver of any other default or breach, whether of the same or other covenant or condition. No waiver, benefit, privilege, or service voluntarily given or performed by a Party shall give the other Party any contractual rights by custom, estoppel, or otherwise.

3.7.16 No Third-Party Beneficiaries. There are no intended third party beneficiaries of any right or obligation assumed by the Parties.

3.7.17 Invalidity; Severability. If any portion of this Agreement is declared invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect.

3.7.18 Prohibited Interests. Consultant maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Consultant, to solicit or secure this Agreement. Consultant warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. Consultant further agrees to file, or shall cause its employees or subconsultants to file, a Statement of Economic Interest with the City’s Filing Officer as required under state law in the performance of the Services. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability. For the term of this Agreement, no member, officer or employee of City, during the term of his or her service with City, shall have any direct interest in this Agreement, or obtain any present or anticipated material benefit arising therefrom.

3.7.19 Authority to Enter Agreement. Consultant has all requisite power and authority to conduct its business and to execute, deliver, and perform the Agreement. Each Party warrants that the individuals who have signed this Agreement have the legal power, right, and authority to make this Agreement and bind each respective Party. 828
46700.00100\40935195.1
BB&K (2023) -16- PROFESSIONAL SERVICES AGREEMENT

3.7.20 Counterparts. This Agreement may be signed in counterparts, each of which shall constitute an original.

3.7.21 Survival. All rights and obligations hereunder that by their nature are to continue after any expiration or termination of this Agreement, including, but not limited to, the indemnification obligations, shall survive any such expiration or termination.

SIGNATURES ON NEXT PAGE
829
46700.00100\40935195.1
BB&K (2023) -17- PROFESSIONAL SERVICES AGREEMENT

SIGNATURE PAGE TO PROFESSIONAL SERVICES AGREEMENT

BETWEEN THE CITY OF ONTARIO AND
Resources Logistics, Inc.

IN WITNESS WHEREOF, each of the Parties has caused this Agreement to be executed on the day and year first above written.

CITY OF ONTARIO Resource Logistics, Inc.

By: AAA
Its: BBB
Printed Name: CCC
By: DDD
Its: EEE
Printed Name: FFF
[If Corporation, TWO SIGNATURES,
President OR Vice President AND Secretary
OR Treasurer REQUIRED]
Approved By:

Scott Ochoa
City Manager
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:

City Clerk
830
46700.00100\40935195.1
BB&K (2023) Exhibit “A”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "A"

SCOPE OF SERVICES

PROPOSED SCOPE OF SERVICES
831
46700.00100\40935195.1
BB&K (2023) Exhibit “B”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "B"

SCHEDULE OF SERVICES
832
46700.00100\40935195.1
BB&K (2023) Exhibit “C”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "C"

COMPENSATION
833
46700.00100\40935195.1
BB&K (2023) Exhibit “C”-1 PROFESSIONAL SERVICES AGREEMENT

CITY OF ONTARIO

PROFESSIONAL SERVICES AGREEMENT

1. PARTIES AND DATE.

This Agreement is made and entered as of ____________, by and between the City of Ontario, a municipal corporation organized under the laws of the State of California with its principal place of business at 303 East “B” Street, Ontario, California 91764-4196, County of San Bernardino, State of California ("City") and SoftHQ, Inc., a Corporation, with its principal place of business at 6494 Weathers Place, Suite 200, San Diego, CA 92121 (“Consultant”). City and Consultant are sometimes individually referred to herein as "Party" and collectively as "Parties."

2. RECITALS.

2.1 Consultant.

Consultant desires to perform and assume responsibility for the provision of certain professional services required by the City on the terms and conditions set forth in this Agreement.

Consultant represents that it is experienced in providing temporary staffing services to public clients, is licensed in the State of California, and is familiar with the plans of City.

2.2 Project.

City desires to engage Consultant to render such professional services for temporary staffing services for the City on an as-needed basis (“Project”) as set forth in this Agreement.

3. TERMS.

3.1 Scope of Services and Term.

3.1.1 General Scope of Services. Consultant promises and agrees to furnish to the City all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply the professional temporary staffing consulting services necessary for the Project ("Services"). The Services are more particularly described in Exhibit "A" attached hereto and incorporated herein by reference. All Services shall be subject to, and performed in accordance with, this Agreement, the exhibits attached hereto and incorporated herein by reference, and all applicable local, state and federal laws, rules and regulations.

PAUL S. LEON
MAYOR

DEBRA PORADA

MAYOR PRO TEM
ALAN D. WAPNER
JIM W. BOWMAN

RUBEN VALENCIA

COUNCIL MEMBERS

SHEILA MAUTZ

CITY CLERK
JAMES R. MILHISER

TREASURER

SCOTT OCHOA

CITY MANAGER
834
46700.00100\40935195.1
BB&K (2023) -2- PROFESSIONAL SERVICES AGREEMENT

3.1.2 Term. The term of this Agreement shall be from November 21, 2023 to November 21, 2026, unless earlier terminated as provided herein. The City shall have the unilateral option, at its sole discretion, to renew this Agreement automatically for no more than two (2) additional one-year terms, unless earlier terminated as provided herein. Consultant shall complete the Services within the term of this Agreement and shall meet any other established schedules and deadlines. The Parties may, by mutual, written consent, extend the term of this Agreement if necessary to complete the Services.

3.2 Compensation.

3.2.1 Compensation. Consultant shall receive compensation, including authorized reimbursements, for all Services rendered under this Agreement at the rates set forth in Exhibit "C" attached hereto and incorporated herein by reference. The total compensation shall not exceed One Million Three Hundred Thousand Dollars and Zero Cents ($1,300,000) without written approval of the City Council or City Manager, as applicable. Extra Work may be authorized, as described below, and if authorized, will be compensated at the rates and manner set forth in this Agreement.

3.2.2 Payment of Compensation. Consultant shall submit to City a monthly invoice which indicates work completed and hours of Services rendered by Consultant. The invoice shall describe the amount of Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the invoice.

City shall, within 30 days of receiving such invoice, review the invoice and pay all non-disputed and approved charges. If the City disputes any of Consultant's fees, the City shall give written notice to Consultant within thirty (30) days of receipt of an invoice of any disputed fees set forth therein. Payment shall not constitute acceptance of any Services completed by Consultant. The making of final payment shall not constitute a waiver of any claims by the City for any reason whatsoever.

3.2.3 Reimbursement for Expenses. Consultant shall not be reimbursed for any expenses unless authorized in writing by City, or included in Exhibit "C" of this Agreement.

3.2.4 Extra Work. At any time during the term of this Agreement, City may request that Consultant perform Extra Work. As used herein, "Extra Work" means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement.

Consultant shall not perform, nor be compensated for, Extra Work without written authorization from the City.

3.3 Responsibilities of Consultant.

3.3.1 Independent Contractor; Control and Payment of Subordinates. The Services shall be performed by Consultant or under its supervision. Consultant will determine the means, methods and details of performing the Services subject to the requirements of this Agreement. City retains Consultant on an independent contractor basis and not as an employee.

Any personnel performing the Services on behalf of Consultant shall not be employees of City and shall at all times be under Consultant's exclusive direction and control. Neither City, or any of its officials, officers, directors, employees or agents shall have control over the conduct of Consultant or any of Consultants officers, employees or agents, except as set forth in this Agreement. Consultant shall pay all wages, salaries, and other amounts due such personnel in 835
46700.00100\40935195.1
BB&K (2023) -3- PROFESSIONAL SERVICES AGREEMENT
connection with their performance of Services under this Agreement and as required by law.

Consultant shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers' compensation insurance.

3.3.2 Schedule of Services. Consultant shall perform the Services in a prompt and timely manner and in accordance with the Schedule of Services set forth in Exhibit "B" attached hereto and incorporated herein by reference. Consultant represents that it has the professional and technical personnel required to perform the Services expeditiously. Upon request of City, Consultant shall provide a more detailed schedule of anticipated performance to meet the Schedule of Services.

3.3.3 Conformance to Applicable Requirements. All work prepared by Consultant shall be subject to the approval of City.

3.3.4 Substitution of Key Personnel. Consultant has represented to City that certain key personnel will perform and coordinate the Services under this Agreement. Should one or more of such personnel become unavailable, Consultant may substitute other personnel of at least equal competence upon written approval of City. In the event that City and Consultant cannot agree as to the substitution of key personnel, City shall be entitled to terminate this Agreement for cause. The key personnel for performance of this Agreement are as follows:

Kranti Ponnam, President.

3.3.5 City's Representative. The City hereby designates Angela Lopez, Executive Director Human Resources/Risk Management, or his/her designee, to act as its representative in all matters pertaining to the administration and performance of this Agreement ("City's Representative"). City's Representative shall have the power to act on behalf of the City for review and approval of all products submitted by Consultant but not the authority to enlarge the Scope of Services or change the total compensation due to Consultant under this Agreement.

The City Manager shall be authorized to act on City's behalf and to execute all necessary documents which enlarge the Scope of Services or change the Consultant's total compensation subject to the provisions contained in this Agreement. Consultant shall not accept direction or orders from any person other than the City Manager, City's Representative or his/her designee.

3.3.6 Consultant's Representative. Consultant hereby designates Kranti Ponnam, President, or his/her designee, to act as its representative for the performance of this Agreement ("Consultant's Representative"). Consultant's Representative shall have full authority to represent and act on behalf of the Consultant for all purposes under this Agreement. The Consultant's Representative shall supervise and direct the Services, using his/her best skill and attention, and shall be responsible for all means, methods, techniques, sequences, and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.

3.3.7 Coordination of Services. Consultant agrees to work closely with City staff in the performance of Services and shall be available to City's staff, consultants and other staff at all reasonable times.

3.3.8 Standard of Care; Performance of Employees. Consultant shall perform all Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals in the same discipline in the State of 836
46700.00100\40935195.1
BB&K (2023) -4- PROFESSIONAL SERVICES AGREEMENT
California. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services. Consultant warrants that all employees and subconsultants shall have sufficient skill and experience to perform the Services assigned to them. Consultant represents that it, its employees and subconsultants have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services, and that such licenses and approvals shall be maintained throughout the term of this Agreement. Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant's failure to comply with the standard of care provided for herein. Any employee of the Consultant or its subconsultants who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed from the Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.

3.3.9 Period of Performance.

3.3.9.1 Consultant shall perform and complete all Services under this Agreement within the term set forth in Section 3.1.2 above (“Performance Time”). Consultant shall also perform the Services in strict accordance with any completion schedule or Project milestones described in Exhibits “A” or “B” attached hereto, or which may be separately agreed upon in writing by the City and Consultant (“Performance Milestones”). Consultant agrees that if the Services are not completed within the aforementioned Performance Time and/or pursuant to any such Performance Milestones developed pursuant to provisions of this Agreement, it is understood, acknowledged and agreed that the City will suffer damage.

3.3.9.2 Neither City nor Consultant shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the non-performing Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Consultant and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the services and Agreement.

3.3.9.3 Should a Force Majeure Event occur, the non-performing Party shall, within a reasonable time of being prevented from performing, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events and/or delays, regardless of the Party responsible for the delay, shall not entitle Consultant to any additional compensation.

Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement. 837
46700.00100\40935195.1
BB&K (2023) -5- PROFESSIONAL SERVICES AGREEMENT

3.3.10 Laws and Regulations; Employee/Labor Certification.

3.3.10.1 Compliance with Laws. Consultant shall keep itself fully informed of and in compliance with all local, state and federal laws, rules and regulations in any manner affecting the performance of the Project or the Services, including all Cal/OSHA requirements, and shall give all notices required by law. Consultant shall be liable for all violations of such laws and regulations in connection with the Services and this Agreement. All violations of such laws and regulations shall be grounds for the City to terminate the Agreement for cause.

3.3.10.2 Employment Eligibility; Consultant. Consultant certifies that it fully complies with all requirements and restrictions of state and federal law respecting the employment of undocumented aliens, including, but not limited to, the Immigration Reform and Control Act of 1986, as may be amended from time to time and shall require all subconsultants and sub-subconsultants to comply with the same. Consultant certifies that it has not committed a violation of any such law within the five (5) years immediately preceding the date of execution of this Agreement, and shall not violate any such law at any time during the term of the Agreement.

3.3.10.3 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subconsultant, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination. Consultant shall also comply with all relevant provisions of City's Minority Business Enterprise program, Affirmative Action Plan or other related programs or guidelines currently in effect or hereinafter enacted.

3.3.10.4 Air Quality. To the extent applicable, Consultant must fully comply with all applicable laws, rules and regulations in furnishing or using equipment and/or providing services, including, but not limited to, emissions limits and permitting requirements imposed by the South Coast Air Quality Management District (SCAQMD) and/or California Air Resources Board (CARB). Consultant shall indemnify City against any fines or penalties imposed by SCAQMD, CARB, or any other governmental or regulatory agency for violations of applicable laws, rules and/or regulations by Consultant, its subconsultants, or others for whom Consultant is responsible under its indemnity obligations provided for in this Agreement.

3.3.10.5 Water Quality Management and Compliance. Consultant shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Services including, without limitation, all applicable provisions of the City’s ordinances regulating water quality and storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251, et seq.); the California Porter-Cologne Water Quality Control Act (Water Code § 13000 et seq.); and any and all regulations, policies, or permits issued pursuant to any such authority. Consultant must additionally comply with the lawful requirements of the City, and any other municipality, drainage district, or other local agency with jurisdiction over the location where the Services are to be conducted, regulating water quality and storm water discharges. City may seek damages from Consultant for delay in completing the Services caused by Consultant’s failure to comply with the laws, regulations and policies described in this Section, or any other relevant water quality law, regulation, or policy.
838
46700.00100\40935195.1
BB&K (2023) -6- PROFESSIONAL SERVICES AGREEMENT

3.3.10.6 Safety. Consultant shall execute and maintain its work so as to avoid injury or damage to any person or property. In carrying out its Services, the Consultant shall at all times be in compliance with all applicable local, state and federal laws, rules and regulations, and shall exercise all necessary precautions for the safety of employees appropriate to the nature of the work and the conditions under which the work is to be performed.

3.3.11 Insurance.

3.3.11.1 Time for Compliance. Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurance required under this section. Failure to provide and maintain all required insurance shall be grounds for the City to terminate this Agreement for cause.

3.3.11.2 Types of Insurance Required. As a condition precedent to the effectiveness of this Agreement for work to be performed hereunder, and without limiting the indemnity provisions of the Agreement, the Consultant, in partial performance of its obligations under such Agreement, shall procure and maintain in full force and effect during the term of the Agreement the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Consultant agrees to amend, supplement or endorse the policies to do so.
(A) Commercial General Liability: Commercial General Liability Insurance which affords coverage at least as broad as Insurance Services Office "occurrence" form CG 00 01, or the exact equivalent, with limits of not less than $2,000,000 per occurrence and no less than $4,000,000 in the general aggregate. Defense costs shall be paid in addition to the limits. The policy shall contain no endorsements or provisions (1) limiting coverage for contractual liability; (2) excluding coverage for claims or suits by one insured against another (cross-liability); (3) products/completed operations liability; or (4) containing any other exclusion(s) contrary to the terms or purposes of this Agreement. (B) Automobile Liability Insurance: Automobile Liability Insurance with coverage at least as broad as Insurance Services Office Form CA 00 01 covering "Any Auto" (Symbol 1), or the exact equivalent, covering bodily injury and property damage for all activities with limits of not less than $2,000,000 combined limit for each occurrence. (C) Workers' Compensation: Workers' Compensation
Insurance, as required by the State of California and Employer's Liability Insurance with a limit of not less than $1,000,000 per accident for bodily injury and disease. (D) Professional Liability (Errors & Omissions): Professional Liability insurance or Errors & Omissions insurance appropriate to Consultant’s profession with limits of not less than $2,000,000. Covered professional services shall specifically include all work to be performed under the Agreement and delete any exclusions that may potentially affect the work to be performed (for example, any exclusions relating to lead, asbestos, pollution, testing, underground storage tanks, laboratory analysis, soil work, etc.). If coverage is written on a claims-made basis, the retroactive date shall precede the effective date of the initial Agreement and continuous coverage will be maintained or an extended reporting period will be exercised for a period of at least five (5) years from termination or expiration of this Agreement. 839
46700.00100\40935195.1
BB&K (2023) -7- PROFESSIONAL SERVICES AGREEMENT

3.3.11.3 Insurance Endorsements. Required insurance policies shall contain the following provisions, or Consultant shall provide endorsements on forms approved by the City to add the following provisions to the insurance policies:
(A) Commercial General Liability: (1) Additional Insured: The City, its officials, officers, employees, agents, and volunteers shall be additional insureds with regard to liability and defense of suits or claims arising out of the performance of the Agreement.

Additional Insured Endorsements shall not (1) be restricted to "ongoing operations"; (2) exclude "contractual liability"; (3) restrict coverage to "sole" liability of Consultant; or (4) contain any other exclusions contrary to the terms or purposes of this Agreement. For all policies of Commercial General Liability insurance, Consultant shall provide endorsements in the form of ISO CG 20 10 10 01 and 20 37 10 01 (or endorsements providing the exact same coverage) to effectuate this requirement. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (B) Automobile Liability: (1) Additional Insured: The City, its directors, officials, officers, employees, agents, and volunteers shall be covered as additional insureds with respect to the ownership, operation, maintenance, use, loading or unloading of any auto owned, leased, hired or borrowed by the Vendor or for which the Vendor is responsible. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium.
(C) Professional Liability (Errors & Omissions): 1) Cancellation:

Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) This insurance shall be written on a policy form coverage specifically designed to protect against acts, errors or omissions of the Consultant. “Covered Professional Services” as designated in the policy must specifically include work performed under this Agreement. The policy must “pay on behalf of” the insured and include a provision establishing the insurer’s duty to defend.
(D) Workers' Compensation: (1) Cancellation: Required
insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) Waiver of Subrogation: A waiver of subrogation stating that the insurer waives all rights of subrogation against the City, its officials, officers, employees, agents, and volunteers.

3.3.11.4 Primary and Non-Contributing Insurance. All policies of Commercial General Liability and Automobile Liability insurance shall be primary and any other insurance, deductible, or self-insurance maintained by the City, its officials, officers, employees, agents, or volunteers shall not contribute with this primary insurance. Policies shall contain or be endorsed to contain such provisions.

3.3.11.5 Waiver of Subrogation. All required insurance coverages, except for the professional liability coverage, shall contain or be endorsed to waiver of subrogation in favor of the City, its officials, officers, employees, agents, and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these specifications 840
46700.00100\40935195.1
BB&K (2023) -8- PROFESSIONAL SERVICES AGREEMENT
to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants.

3.3.11.6 Deductibles and Self-Insured Retentions. Any deductible or selfinsured retention must be approved in writing by the City and shall protect the City, its officials, officers, employees, agents, and volunteers in the same manner and to the same extent as they would have been protected had the policy or policies not contained a deductible or self-insured retention.

3.3.11.7 Evidence of Insurance. The Consultant, concurrently with the execution of the Agreement, and as a condition precedent to the effectiveness thereof, shall deliver either certified copies of the required policies, or original certificates on forms approved by the City, together with all endorsements affecting each policy. Required insurance policies shall not be in compliance if they include any limiting provision or endorsement that has not been submitted to the City for approval. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf. At least fifteen (15 days) prior to the expiration of any such policy, evidence of insurance showing that such insurance coverage has been renewed or extended shall be filed with the City. If such coverage is cancelled or reduced and not replaced immediately so as to avoid a lapse in the required coverage, Consultant shall, within ten (10) days after receipt of written notice of such cancellation or reduction of coverage, file with the City evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies.

3.3.11.8 Acceptability of Insurers. Each such policy shall be from a company or companies with a current A.M. Best's rating of no less than A:VII and authorized to transact business of insurance in the State of California, or otherwise allowed to place insurance through surplus line brokers under applicable provisions of the California Insurance Code or any federal law.

3.3.11.9 Enforcement of Agreement Provisions (non estoppel).

Consultant acknowledges and agrees that actual or alleged failure on the part of the City to inform Consultant of non-compliance with any requirement imposes no additional obligation on the City nor does it waive any rights hereunder.

3.3.11.10 Requirements Not Limiting. Requirement of specific coverage or minimum limits contained in this Section are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance.

3.3.11.11 Additional Insurance Provisions
(A) The foregoing requirements as to the types and limits of insurance coverage to be maintained by Consultant, and any approval of said insurance by the City, is not intended to and shall not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Consultant pursuant to this Agreement, including but not limited to, the provisions concerning indemnification.
(B) If at any time during the life of the Agreement, any policy of insurance required under this Agreement does not comply with these specifications or is canceled 841
46700.00100\40935195.1
BB&K (2023) -9- PROFESSIONAL SERVICES AGREEMENT
and not replaced, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Consultant or City will withhold amounts sufficient to pay premium from Consultant payments. In the alternative, City may cancel this Agreement.
(C) The City may require the Consultant to provide complete copies of all insurance policies in effect for the duration of the Project. (D) Neither the City nor any of its officials, officers, employees, agents or volunteers shall be personally responsible for any liability arising under or by virtue of this Agreement.
(E) The limits set forth herein shall apply separately to each insured against whom claims are made or suits are brought, except with respect to the limits of liability. Further the limits set forth herein shall not be construed to relieve the Consultant from liability in excess of such coverage, nor shall it limit the Consultant’s indemnification obligations to the City and shall not preclude the City from taking such other actions available to the City under other provisions of the Agreement or law.
(F) Consultant shall report to the City, in addition to Consultant’s insurer, any and all insurance claims submitted by Consultant in connection with the Services under this Agreement.

3.3.11.12 Insurance for Subconsultants. Consultant shall include all subconsultants engaged in any work for Consultant relating to this Agreement as additional insureds under the Consultant's policies, or the Consultant shall be responsible for causing subconsultants to purchase the appropriate insurance in compliance with the terms of these Insurance Requirements, including adding the City, its officials, officers, employees, agents, and volunteers as additional insureds to the subconsultant's policies. All policies of Commercial General Liability insurance provided by Consultant’s subconsultants performing work relating to this Agreement shall be endorsed to name the City, its officials, officers, employees, agents and volunteers as additional insureds using endorsement form ISO CG 20 38 04 13 or an endorsement providing equivalent coverage. Consultant shall not allow any subconsultant to commence work on any subcontract relating to this Agreement until it has received satisfactory evidence of subconsultant’s compliance with all insurance requirements under this Agreement, to the extent applicable. The Consultant shall provide satisfactory evidence of compliance with this section upon request of the City.

3.4 Labor Code Requirements.

3.4.1 Prevailing Wages. Consultant is aware of the requirements of California Labor Code Section 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., ("Prevailing Wage Laws"), which require the payment of prevailing wage rates and the performance of other requirements on "public works" and "maintenance" projects. If the Services are being performed as part of an applicable "public works" or "maintenance" project, as defined by the Prevailing Wage Laws, and if the total compensation is $1,000 or more, Consultant agrees to fully comply with such Prevailing Wage Laws. City shall provide Consultant with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Consultant shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services 842
46700.00100\40935195.1
BB&K (2023) -10- PROFESSIONAL SERVICES AGREEMENT
available to interested parties upon request, and shall post copies at the Consultant's principal place of business and at the project site. It is the intent of the parties to effectuate the requirements of sections 1771, 1774, 1775, 1776, 1777.5, 1813, and 1815 of the Labor Code within this Agreement, and Consultant shall therefore comply with such Labor Code sections to the fullest extent required by law. Consultant shall defend, indemnify and hold the City, its officials, officers, employees, agents, and volunteers free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws.

3.4.2 Registration/DIR Compliance. If the Services are being performed on a public works project of over $25,000 when the project is for construction, alteration, demolition, installation, or repair work, or a public works project of over $15,000 when the project is for maintenance work, in addition to the foregoing, then pursuant to Labor Code sections 1725.5 and 1771.1, the Consultant and all subconsultants must be registered with the Department of Industrial Relations (“DIR”). Consultant shall maintain registration for the duration of the Project and require the same of any subconsultants.

3.4.3 Compliance Monitoring. This Project may also be subject to compliance monitoring and enforcement by the DIR. It shall be Consultant’s sole responsibility to comply with all applicable registration and labor compliance requirements, including the submission of payroll records directly to the DIR. Any stop orders issued by the DIR against Consultant or any subconsultant that affect Consultant’s performance of services, including any delay, shall be Consultant’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Consultant caused delay and shall not be compensable by the City. Consultant shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the DIR against Consultant or any subconsultant.

3.4.4 Labor Certification. By its signature hereunder, Consultant certifies that it is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker's Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services.

3.5 Termination of Agreement.

3.5.1.1 Grounds for Termination. City may, by written notice to Consultant, terminate the whole or any part of this Agreement at any time and without cause by giving written notice to Consultant of such termination, and specifying the effective date thereof, at least seven (7) days before the effective date of such termination. Upon termination, Consultant shall be compensated only for those Services which have been adequately rendered to City, and Consultant shall be entitled to no further compensation. Consultant may not terminate this Agreement except for cause. The rights and remedies of the City provided in this section shall not be exclusive and are in addition to any other rights and remedies provided by law, equity or under this Agreement.

3.5.1.2 Effect of Termination. If this Agreement is terminated as provided herein, City may require Consultant to provide all finished or unfinished Documents and Data and other information of any kind prepared by Consultant in connection with the performance of Services under this Agreement. Consultant shall be required to provide such document and other information within fifteen (15) days of the request. 843
46700.00100\40935195.1
BB&K (2023) -11- PROFESSIONAL SERVICES AGREEMENT

3.5.1.3 Additional Services. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated.

3.6 Indemnification.

3.6.1 To the fullest extent permitted by law, Consultant shall defend (with counsel of City’s choosing), indemnify and hold the City, its officials, officers, employees, volunteers, and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Consultant, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Consultant’s Services, the Project or this Agreement, including without limitation the payment of all damages, expert witness fees and attorney’s fees and other related costs and expenses except such loss or damage caused by the sole negligence or willful misconduct of the City. Consultant's obligation to indemnify shall survive expiration or termination of this Agreement and shall not be restricted to insurance proceeds, if any, received by Consultant, the City, its officials, officers, employees, agents, or volunteers.

3.6.2 If Consultant’s obligation to defend, indemnify, and/or hold harmless arises out of Consultant’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Consultant’s indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Consultant, and, upon Consultant obtaining a final adjudication by a court of competent jurisdiction, Consultant’s liability for such claim, including the cost to defend, shall not exceed the Consultant’s proportionate percentage of fault.

3.7 General Provisions.

3.7.1 Accounting Records. Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to this Agreement. Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement.

3.7.2 Independent Contractors and Subcontracting.

3.7.2.1 Use of Consultants. Consultant is aware of statutory and case law regarding classification of workers as independent contractors, including California Labor Code Section 2750.3 and Dynamex Operations West, Inc. v. Superior Court, 4 Cal. 5th 903 (2018). To ensure that Consultant is in compliance with the California Labor Code, Consultant shall only utilize its employees to provide the Services. Consultant may not provide the services through any independent contractor, subcontractor or subconsultant (“Subcontractor(s)”) unless approved by the City as set forth in Section 3.7.2.2 below. Consultant represents and warrants that all personnel who perform the Services on Consultant’s behalf are Consultant’s employees, and that Consultant complies with all applicable laws, rules and regulations governing its 844
46700.00100\40935195.1
BB&K (2023) -12- PROFESSIONAL SERVICES AGREEMENT
employees, including, but not limited to, the California Labor Code, Unemployment Insurance Code and all applicable Industrial Welfare Commission Wage Orders.

3.7.2.2 Prior Approval Required. Consultant shall not use any Subcontractor to provide the Services, or any portion of the work required by this Agreement, without prior written approval of City. In the event that City authorizes Consultant to use a Subcontractor, Consultant shall enter into a written agreement with the Subcontractor, which must include all provisions of the Agreement, including a restriction on the Subcontractor’s use of further independent contractors, subcontractors or subconsultants without the City’s prior written consent.

3.7.3 Delivery of Notices. All notices permitted or required under this Agreement shall be given to the respective parties at the following address, or at such other address as the respective parties may provide in writing for this purpose:

Consultant: SoftHQ, Inc.
6494 Weathers Place, Suite 200,
San Diego, CA 32121
ATTN: Kranti Ponnam, President
City: City of Ontario
303 East “B” Street
Ontario, CA 91764
ATTN: Angela Lopez, Executive Director Human
Resources/Risk Management
Such notice shall be deemed made when personally delivered or when mailed, forty-eight (48) hours after deposit in the U.S. Mail, first class postage prepaid and addressed to the party at its applicable address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.

3.7.4 Ownership of Materials and Confidentiality.

3.7.4.1 Documents & Data; Licensing of Intellectual Property. This Agreement creates a non-exclusive and perpetual license for City to copy, use, modify, reuse, or sublicense any and all copyrights, designs, and other intellectual property embodied in plans, specifications, studies, drawings, estimates, and other documents or works of authorship fixed in any tangible medium of expression, including but not limited to, physical drawings or data magnetically or otherwise recorded on computer diskettes, which are prepared or caused to be prepared by Consultant under this Agreement ("Documents & Data"). All Documents & Data shall be and remain the property of City, and shall not be used in whole or in substantial part by Consultant on other projects without the City’s express written permission. Within thirty (30) days following the completion, suspension, abandonment or termination of this Agreement, Consultant shall provide to City reproducible copies of all Documents & Data, in a form and amount required by City. City reserves the right to select the method of document reproduction and to establish where the reproduction will be accomplished. The reproduction expense shall be borne by City at the actual cost of duplication. In the event of a dispute regarding the amount of compensation to which the Consultant is entitled under the termination provisions of this Agreement, Consultant shall provide all Documents & Data to City upon payment of the undisputed amount. Consultant shall have no right to retain or fail to provide to City any such documents pending resolution of 845
46700.00100\40935195.1
BB&K (2023) -13- PROFESSIONAL SERVICES AGREEMENT
the dispute. In addition, Consultant shall retain copies of all Documents & Data on file for a minimum of fifteen (15) years following completion of the Project, and shall make copies available to City upon the payment of actual reasonable duplication costs. Before destroying the Documents & Data following this retention period, Consultant shall make a reasonable effort to notify City and provide City with the opportunity to obtain the documents.

3.7.4.2 Subconsultants. Consultant shall require all subconsultants to agree in writing that City is granted a non-exclusive and perpetual license for any Documents & Data the subconsultant prepares under this Agreement. Consultant represents and warrants that Consultant has the legal right to license any and all Documents & Data. Consultant makes no such representation and warranty in regard to Documents & Data which were prepared by design professionals other than Consultant or its subconsultants, or those provided to Consultant by the City.

3.7.4.3 Right to Use. City shall not be limited in any way in its use or reuse of the Documents and Data or any part of them at any time for purposes of this Project or another project, provided that any such use not within the purposes intended by this Agreement or on a project other than this Project without employing the services of Consultant shall be at City’s sole risk. If City uses or reuses the Documents & Data on any project other than this Project, it shall remove the Consultant’s seal from the Documents & Data and indemnify and hold harmless Consultant and its officers, directors, agents and employees from claims arising out of the negligent use or re-use of the Documents & Data on such other project. Consultant shall be responsible and liable for its Documents & Data, pursuant to the terms of this Agreement, only with respect to the condition of the Documents & Data at the time they are provided to the City upon completion, suspension, abandonment or termination. Consultant shall not be responsible or liable for any revisions to the Documents & Data made by any party other than Consultant, a party for whom the Consultant is legally responsible or liable, or anyone approved by the Consultant.

3.7.4.4 Indemnification. Consultant shall defend, indemnify and hold the City, its directors, officials, officers, employees, volunteers and agents free and harmless, pursuant to the indemnification provisions of this Agreement, for any alleged infringement of any patent, copyright, trade secret, trade name, trademark, or any other proprietary right of any person or entity in consequence of the use on the Project by City of the Documents & Data, including any method, process, product, or concept specified or depicted.

3.7.4.5 Confidentiality. All ideas, memoranda, specifications, plans, procedures, drawings, descriptions, computer program data, input record data, written information, and other Documents & Data either created by or provided to Consultant in connection with the performance of this Agreement shall be held confidential by Consultant. Such materials shall not, without the prior written consent of City, be used by Consultant for any purposes other than the performance of the Services. Nor shall such materials be disclosed to any person or entity not connected with the performance of the Services or the Project. Nothing furnished to Consultant which is otherwise known to Consultant or is generally known, or has become known, to the related industry shall be deemed confidential. Consultant shall not use City's name or insignia, photographs of the Project, or any publicity pertaining to the Services or the Project in any magazine, trade paper, newspaper, television or radio production or other similar medium without the prior written consent of City. 846
46700.00100\40935195.1
BB&K (2023) -14- PROFESSIONAL SERVICES AGREEMENT

3.7.4.6 Confidential Information. The City shall refrain from releasing Consultant’s proprietary information ("Proprietary Information") unless the City's legal counsel determines that the release of the Proprietary Information is required by the California Public Records Act or other applicable state or federal law, or order of a court of competent jurisdiction, in which case the City shall notify Consultant of its intention to release Proprietary Information.

Consultant shall have five (5) working days after receipt of the release notice to give City written notice of Consultant's objection to the City's release of Proprietary Information. Consultant shall indemnify, defend and hold harmless the City, and its officers, directors, employees, and agents from and against all liability, loss, cost or expense (including attorney’s fees) arising out of a legal action brought to compel the release of Proprietary Information. City shall not release the Proprietary Information after receipt of an objection notice unless either: (1) Consultant fails to fully indemnify, defend (with City's choice of legal counsel), and hold City harmless from any legal action brought to compel such release; and/or (2) a final and non-appealable order by a court of competent jurisdiction requires that City release such information.

3.7.5 Cooperation; Further Acts. The Parties shall fully cooperate with one another, and shall take any additional acts or sign any additional documents as may be necessary, appropriate or convenient to attain the purposes of this Agreement.

3.7.6 Entire Agreement. This Agreement contains the entire agreement of the Parties with respect to the subject matter hereof, and supersedes all prior negotiations, understandings or agreements.

3.7.7 Attorneys’ Fees. If either party commences an action against the other party, either legal, administrative or otherwise, arising out of or in connection with this Agreement, the prevailing party in such litigation shall be entitled to have and recover from the losing party reasonable attorneys’ fees and all costs of such action.

3.7.8 Governing Law. This Agreement shall be governed by the laws of the State of California. Venue shall be in San Bernardino County. In addition to any and all contract requirements pertaining to notices of and requests for compensation or payment for extra work, disputed work, claims and/or changed conditions, Consultant must comply with the claim procedures set forth in Government Code sections 900 et seq. prior to filing any lawsuit against the City. Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to extra work, disputed work, claims, and/or changed conditions have been followed by Consultant. If no such Government Code claim is submitted, or if any prerequisite contractual requirements are not otherwise satisfied as specified herein, Consultant shall be barred from bringing and maintaining a valid lawsuit against the City.

3.7.9 Time of Essence. Time is of the essence for each and every provision of this Agreement.

3.7.10 City's Right to Employ Other Consultants. City reserves right to employ other consultants in connection with this Project.

3.7.11 Successors and Assigns. This Agreement shall be binding on the successors and assigns of the parties.

3.7.12 Assignment or Transfer. Consultant shall not assign, sublet, or transfer this 847
46700.00100\40935195.1
BB&K (2023) -15- PROFESSIONAL SERVICES AGREEMENT
Agreement or any rights under or interest in this Agreement without the written consent of the City, which may be withheld for any reason. Any attempt to so assign or so transfer without such consent shall be void and without legal effect and shall constitute grounds for termination.

Consultant shall not subcontract any portion of the Services required by this Agreement, except as expressly stated herein, without prior written approval of City. Subcontracts, if any, shall contain a provision making them subject to all provisions stipulated in this Agreement.

3.7.13 Construction; References; Captions. Since the Parties or their agents have participated fully in the preparation of this Agreement, the language of this Agreement shall be construed simply, according to its fair meaning, and not strictly for or against any Party. Any term referencing time, days or period for performance shall be deemed calendar days and not work days. All references to Consultant include all personnel, employees, agents, and subconsultants of Consultant, except as otherwise specified in this Agreement. All references to City include its elected officials, officers, employees, agents, and volunteers except as otherwise specified in this Agreement. The captions of the various articles and paragraphs are for convenience and ease of reference only, and do not define, limit, augment, or describe the scope, content, or intent of this Agreement.

3.7.14 Amendment; Modification. No supplement, modification, or amendment of this Agreement shall be binding unless executed in writing and signed by both Parties.

3.7.15 Waiver. No waiver of any default shall constitute a waiver of any other default or breach, whether of the same or other covenant or condition. No waiver, benefit, privilege, or service voluntarily given or performed by a Party shall give the other Party any contractual rights by custom, estoppel, or otherwise.

3.7.16 No Third-Party Beneficiaries. There are no intended third party beneficiaries of any right or obligation assumed by the Parties.

3.7.17 Invalidity; Severability. If any portion of this Agreement is declared invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect.

3.7.18 Prohibited Interests. Consultant maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Consultant, to solicit or secure this Agreement. Consultant warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. Consultant further agrees to file, or shall cause its employees or subconsultants to file, a Statement of Economic Interest with the City’s Filing Officer as required under state law in the performance of the Services. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability. For the term of this Agreement, no member, officer or employee of City, during the term of his or her service with City, shall have any direct interest in this Agreement, or obtain any present or anticipated material benefit arising therefrom.

3.7.19 Authority to Enter Agreement. Consultant has all requisite power and authority to conduct its business and to execute, deliver, and perform the Agreement. Each Party warrants that the individuals who have signed this Agreement have the legal power, right, and authority to make this Agreement and bind each respective Party. 848
46700.00100\40935195.1
BB&K (2023) -16- PROFESSIONAL SERVICES AGREEMENT

3.7.20 Counterparts. This Agreement may be signed in counterparts, each of which shall constitute an original.

3.7.21 Survival. All rights and obligations hereunder that by their nature are to continue after any expiration or termination of this Agreement, including, but not limited to, the indemnification obligations, shall survive any such expiration or termination.

SIGNATURES ON NEXT PAGE
849
46700.00100\40935195.1
BB&K (2023) -17- PROFESSIONAL SERVICES AGREEMENT

SIGNATURE PAGE TO PROFESSIONAL SERVICES AGREEMENT

BETWEEN THE CITY OF ONTARIO AND
SoftHQ, Inc.

IN WITNESS WHEREOF, each of the Parties has caused this Agreement to be executed on the day and year first above written.

CITY OF ONTARIO SoftHQ Inc.

By: AAA
Its: BBB
Printed Name: CCC
By: DDD
Its: EEE
Printed Name: FFF
[If Corporation, TWO SIGNATURES,
President OR Vice President AND Secretary
OR Treasurer REQUIRED]
Approved By:

Scott Ochoa
City Manager
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:

City Clerk
850
46700.00100\40935195.1
BB&K (2023) Exhibit “A”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "A"

SCOPE OF SERVICES

PROPOSED SCOPE OF SERVICES
851
46700.00100\40935195.1
BB&K (2023) Exhibit “B”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "B"

SCHEDULE OF SERVICES
852
46700.00100\40935195.1
BB&K (2023) Exhibit “C”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "C"

COMPENSATION
853
Department: Broadband Operations
Prepared By: Judy Witrago
Staff Member Presenting:

Jimmy Chang, Broadband General Manager
Approved By:

Submitted To: Council/OHA
Approved: _______________________________
Continued To: ___________________________
Denied: __________________________________
Item No: 18
SUBJECT: AUTHORIZE A CHANGE ORDER TO THE CONSTRUCTION CONTRACT WITH SERVITEK ELECTRIC, INC. FOR THE CDBG CITY FIBER CONDUIT INSTALLATION WEST RING SEGMENT 2

CITY OF ONTARIO
Agenda Report
November 21, 2023
SECTION:

CONSENT CALENDAR
RECOMMENDATION: That the City Council approve a Change Order to the Construction Contract with Servitek Electric, Inc. of Walnut, California, to increase the total authorized expenditure by $21,176 for the CDBG City Fiber Conduit Installation West Ring Segment 2 Project, for a revised total contract not-to-exceed amount of $821,281.

THE FOLLOWING COUNCIL GOALS ARE BEING ACHIEVED:

Invest in the Growth and Evolution of the City's Economy Operate in a Businesslike Manner
Invest in the City's Infrastructure (Water, Streets, Sewers, Parks, Storm Drains and Public Facilities)
FISCAL IMPACT: The Fiscal Year 2023-24 Adopted Budget includes appropriations in the Broadband/Fiber Fund for the construction of City fiber conduit installation. The proposed Change Order will increase the contract by $21,176 for a total not-to-exceed contract amount of $821,281.

BACKGROUND & ANALYSIS: On March 21, 2023, a Construction Contract was awarded to Servitek Electric Inc. for fiber optic conduit installation services in the amount of $731,914 plus a 10% contingency of $73,191, for a total expenditure of $805,105.

During construction in various locations of the project area, it was discovered that the restoration work for sidewalks, driveway approaches, and roadway curbs did not meet the requirements defined by the City’s Engineering Department. In several instances, the original project plans indicated the need to replace single sidewalk panels, while the City's standards dictate the replacement of multiple panels. Moreover, the presence of sidewalks featuring rolled curbs and larger-than-standard sidewalk panel sizes has expanded the scope of restoration work within the right-of-way areas. These unexpected conditions have led to the identification of additional required restoration, which are addressed in this Change Order. 854
855
856
Vendor Name: Servitek Electric, Inc.

Agreement Type: Construction Contract
Description of Scope:

Document Date Value Term Description
Original Agreement From NTP $ 731,914 365 Calendar Days Contingency $ 73,191
Amendment $ 21,176
Total PO 826,281 $
The general scope of work to be performed consists of the installation of underground fiber optic conduit, handholes and locate cable for the purpose of expanding the OntarioNet broadband fiber and wireless network to west Ontario.

Contract/Contingency Recap Worksheet
857
Department: Utilities
Prepared By: Thomas Lambertson
Staff Member Presenting:

Scott Burton, Utilities General Manager
Reviewed By: Dennice Raygoza, Albert G
Gastelum, Michael Sigsbee
Approved By:

Submitted To: Council/OHA
Approved: _______________________________
Continued To: ___________________________
Denied: __________________________________
Item No: 19
SUBJECT: A PROFESSIONAL SERVICES AGREEMENT WITH AKM CONSULTING ENGINEERS FOR THE 2023 POTABLE WATER, RECYCLED WATER, SEWER MASTER PLAN

UPDATES, AND SEWER SYSTEM MANAGEMENT PLAN AND AUDIT

CITY OF ONTARIO
Agenda Report
November 21, 2023
SECTION:

CONSENT CALENDAR
RECOMMENDATION: That the City Council approve and authorize the City Manager, or his designee, to execute a Professional Services Agreement with AKM Consulting Engineers, of Irvine, California, to provide engineering services for the Potable Water, Recycled Water, Sewer Master Plan Updates, and Sewer System Management Plan and Audit for $1,646,784 plus a 10% contingency of $164,678 for a total not-to-exceed contract amount of $1,811,462, and a term from November 21, 2023 to November 21, 2025.

THE FOLLOWING COUNCIL GOALS ARE BEING ACHIEVED:

Invest in the Growth and Evolution of the City's Economy Operate in a Businesslike Manner
Invest in the City's Infrastructure (Water, Streets, Sewers, Parks, Storm Drains and Public Facilities)
Ensure the Development of a Well Planned, Balanced, and Self-Sustaining Community in Ontario Ranch
FISCAL IMPACT: The proposed Agreement is for $1,646,784 plus a 10% contingency of $164,678 for a total not-to-exceed contract amount of $1,811,462. The term of the Agreement will be from November 21, 2023 to November 21, 2025. Funding for this work will be shared between the Capital Water Fund, the Sewer Capital Fund, and the Water and Sewer Regional Development Impact Fee (DIF) Fund (DIF Project No.'s WT-27 and SW-27).

The Fiscal Year 2023-24 Adopted Budged includes appropriations from the Water and Sewer Capital Fund to cover a portion of the cost for engineering services for the Potable Water, Recycled Water, Sewer Master Plan Updates, and Sewer System Management Plan and Audit. If approved, additional appropriations in the Water Capital Fund, Sewer Capital Fund, and Water and Sewer Regional Development Impact Fee Fund will be requested at the next quarterly budget update as needed.

There is no impact to the General Fund.
858
BACKGROUND & ANALYSIS: The City’s water system includes approximately 680 miles of existing main lines (potable and recycled water), 75 million gallons of reservoir storage, and 22 active wells.

The sewer system includes approximately 450 miles of existing main lines and 3 lift stations. The Potable Water Master Plan (WMP) and Recycled Water Master Plan (RWMP) identifies water production, transmission, and distribution system improvements, and the Sewer Master Plan (SMP) identifies the collection and transport system improvements necessary to serve existing and future residents and businesses of the City, all of which is undergoing significant expansion in Ontario Ranch. The hydraulic modeling and analysis of the water and sewer system determines near, and long-term capital improvement needs and subsequent investments. An update to the master plans is required to align the capital needs with the land use changes and densification made in the current 2050 Ontario Plan (TOP), adopted in 2022.

The WMP and RWMP updates will review changing water demands resulting from the 2050 TOP land use changes as well as recent and emerging water use efficiency standards, including State mandated conservation goals, and will include updated water demand factors in the hydraulic analysis. The SMP will similarly review changing sewer demands based on similar factors to determine updated flow and peaking factors in the sewer hydraulic analysis. Within the existing system, operational challenges, and trends (such as water main leaks and sewage spills) are factored into the capital improvement program. Within Ontario Ranch and other rapidly changing areas of the City, the master plan updates will reflect the latest infrastructure conditions and planning for expansion. The existing WMP, RWMP, and SMP were last prepared by AKM Consulting Engineers and adopted by City Council in 2012. Demand factors and hydraulic data were reevaluated by AKM Consulting Engineers and Stantec between 2017 and 2020 based on changing conditions but were not adopted pending the update to the 2050 TOP.

The State Water Resources Control Board adopted Order WQ 2022-0103-DWQ (Statewide Waste Discharge Requirements General Order for Sanitary Sewer Systems) on December 6, 2022, which became effective on June 5, 2023. The Order requires the City to conduct an internal audit and update its Sewer System Management Plan (SSMP) at a minimum once every three years. The City’s SSMP was last audited February 11, 2021, and updated in April 2021. The SSMP describes the activities that an agency uses to effectively manage their wastewater collection system to properly manage, operate, and maintain all parts of the sanitary sewer system, to reduce, prevent, and mitigate sanitary sewer overflows. The audit evaluates the effectiveness of the SSMP to identify deficiencies (if any) and steps to correct them.

On August 22, 2023, two (2) bids were received through the City’s electronic bid management system for Bid No. 1675, Potable Water and Recycled Water Master Plan Updates and Bid No. 1674 Sewer Master Plan Update. Companies that submitted bid are as follows:

Bidder Location
AKM Consulting Engineers Irvine, CA
Ardurra Group Inc. Newport Beach, CA
859
Staff has reviewed the proposals, and negotiated engineering services for the WMP, RWMP, SMP updates, and included the SSMP Update and Audit. Based on their proposal, engineering expertise, knowledge of the City’s systems, successful completion of this type of work in the past, and capability to perform the work in a timely manner, it is recommended to award the Professional Services Agreement to AKM Consulting Engineers.
860
861
46700.00100\40935195.1
BB&K (2023) -2- PROFESSIONAL SERVICES AGREEMENT

3.1.2 Term. The term of this Agreement shall be from November 21, 2023 to November 21, 2025, unless earlier terminated as provided herein. Consultant shall complete the Services within the term of this Agreement, and shall meet any other established schedules and deadlines. The Parties may, by mutual, written consent, extend the term of this Agreement if necessary to complete the Services.

3.2 Compensation.

3.2.1 Compensation. Consultant shall receive compensation, including authorized reimbursements, for all Services rendered under this Agreement at the rates set forth in Exhibit "C" attached hereto and incorporated herein by reference. The total compensation shall not exceed One Million Six Hundred Forty Six Thousand Seven Hundred Eighty Four Dollars and Zero Cents ($1,646,784.00) without written approval of the City Council or City Manager, as applicable. Extra Work may be authorized, as described below, and if authorized, will be compensated at the rates and manner set forth in this Agreement.

3.2.2 Payment of Compensation. Consultant shall submit to City a monthly invoice which indicates work completed and hours of Services rendered by Consultant. The invoice shall describe the amount of Services provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the invoice.

City shall, within 30 days of receiving such invoice, review the invoice and pay all non-disputed and approved charges. If the City disputes any of Consultant's fees, the City shall give written notice to Consultant within thirty (30) days of receipt of an invoice of any disputed fees set forth therein. Payment shall not constitute acceptance of any Services completed by Consultant. The making of final payment shall not constitute a waiver of any claims by the City for any reason whatsoever.

3.2.3 Reimbursement for Expenses. Consultant shall not be reimbursed for any expenses unless authorized in writing by City, or included in Exhibit "C" of this Agreement.

3.2.4 Extra Work. At any time during the term of this Agreement, City may request that Consultant perform Extra Work. As used herein, "Extra Work" means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement.

Consultant shall not perform, nor be compensated for, Extra Work without written authorization from the City.

3.3 Responsibilities of Consultant.

3.3.1 Independent Contractor; Control and Payment of Subordinates. The Services shall be performed by Consultant or under its supervision. Consultant will determine the means, methods and details of performing the Services subject to the requirements of this Agreement. City retains Consultant on an independent contractor basis and not as an employee.

Any personnel performing the Services on behalf of Consultant shall not be employees of City and shall at all times be under Consultant's exclusive direction and control. Neither City, or any of its officials, officers, directors, employees or agents shall have control over the conduct of Consultant or any of Consultants officers, employees or agents, except as set forth in this Agreement. Consultant shall pay all wages, salaries, and other amounts due such personnel in connection with their performance of Services under this Agreement and as required by law.

Consultant shall be responsible for all reports and obligations respecting such additional 862
46700.00100\40935195.1
BB&K (2023) -3- PROFESSIONAL SERVICES AGREEMENT
personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, disability insurance, and workers' compensation insurance.

3.3.2 Schedule of Services. Consultant shall perform the Services in a prompt and timely manner and in accordance with the Schedule of Services set forth in Exhibit "B" attached hereto and incorporated herein by reference. Consultant represents that it has the professional and technical personnel required to perform the Services expeditiously. Upon request of City, Consultant shall provide a more detailed schedule of anticipated performance to meet the Schedule of Services.

3.3.3 Conformance to Applicable Requirements. All work prepared by Consultant shall be subject to the approval of City.

3.3.4 Substitution of Key Personnel. Consultant has represented to City that certain key personnel will perform and coordinate the Services under this Agreement. Should one or more of such personnel become unavailable, Consultant may substitute other personnel of at least equal competence upon written approval of City. In the event that City and Consultant cannot agree as to the substitution of key personnel, City shall be entitled to terminate this Agreement for cause. The key personnel for performance of this Agreement are as follows: Zeki Kayiran, P.E., Principal-in-Charge.

3.3.5 City's Representative. The City hereby designates Dennis Mejia, P.E., Utilities Engineering Division Manager, or his/her designee, to act as its representative in all matters pertaining to the administration and performance of this Agreement ("City's Representative"). City's Representative shall have the power to act on behalf of the City for review and approval of all products submitted by Consultant but not the authority to enlarge the Scope of Services or change the total compensation due to Consultant under this Agreement. The City Manager shall be authorized to act on City's behalf and to execute all necessary documents which enlarge the Scope of Services or change the Consultant's total compensation subject to the provisions contained in this Agreement. Consultant shall not accept direction or orders from any person other than the City Manager, City's Representative or his/her designee.

3.3.6 Consultant's Representative. Consultant hereby designates Zeki Kayiran, P.E., Principal-in-Charge, or his/her designee, to act as its representative for the performance of this Agreement ("Consultant's Representative"). Consultant's Representative shall have full authority to represent and act on behalf of the Consultant for all purposes under this Agreement.

The Consultant's Representative shall supervise and direct the Services, using his/her best skill and attention, and shall be responsible for all means, methods, techniques, sequences, and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.

3.3.7 Coordination of Services. Consultant agrees to work closely with City staff in the performance of Services and shall be available to City's staff, consultants and other staff at all reasonable times.

3.3.8 Standard of Care; Performance of Employees. Consultant shall perform all Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals in the same discipline in the State of California. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services. Consultant warrants that all employees and subconsultants 863
46700.00100\40935195.1
BB&K (2023) -4- PROFESSIONAL SERVICES AGREEMENT
shall have sufficient skill and experience to perform the Services assigned to them. Consultant represents that it, its employees and subconsultants have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services, and that such licenses and approvals shall be maintained throughout the term of this Agreement. Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant's failure to comply with the standard of care provided for herein. Any employee of the Consultant or its subconsultants who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed from the Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.

3.3.9 Period of Performance.

3.3.9.1 Consultant shall perform and complete all Services under this Agreement within the term set forth in Section 3.1.2 above (“Performance Time”). Consultant shall also perform the Services in strict accordance with any completion schedule or Project milestones described in Exhibits “A” or “B” attached hereto, or which may be separately agreed upon in writing by the City and Consultant (“Performance Milestones”). Consultant agrees that if the Services are not completed within the aforementioned Performance Time and/or pursuant to any such Performance Milestones developed pursuant to provisions of this Agreement, it is understood, acknowledged and agreed that the City will suffer damage.

3.3.9.2 Neither City nor Consultant shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the non-performing Party. For purposes of this Agreement, such circumstances include a Force Majeure Event. A Force Majeure Event shall mean an event that materially affects a Party’s performance and is one or more of the following: (1) Acts of God or other natural disasters; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the services); (4) strikes and other organized labor action occurring at the site and the effects thereof on the services, only to the extent such strikes and other organized labor action are beyond the control of Consultant and its subcontractors, and to the extent the effects thereof cannot be avoided by use of replacement workers; and (5) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of a public agency applicable to the services and Agreement.

3.3.9.3 Should a Force Majeure Event occur, the non-performing Party shall, within a reasonable time of being prevented from performing, give written notice to the other Party describing the circumstances preventing continued performance and the efforts being made to resume performance of this Agreement. Force Majeure Events and/or delays, regardless of the Party responsible for the delay, shall not entitle Consultant to any additional compensation.

Notwithstanding the foregoing in this section, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement.

3.3.10 Laws and Regulations; Employee/Labor Certification. 864
46700.00100\40935195.1
BB&K (2023) -5- PROFESSIONAL SERVICES AGREEMENT

3.3.10.1 Compliance with Laws. Consultant shall keep itself fully informed of and in compliance with all local, state and federal laws, rules and regulations in any manner affecting the performance of the Project or the Services, including all Cal/OSHA requirements, and shall give all notices required by law. Consultant shall be liable for all violations of such laws and regulations in connection with the Services and this Agreement. All violations of such laws and regulations shall be grounds for the City to terminate the Agreement for cause.

3.3.10.2 Employment Eligibility; Consultant. Consultant certifies that it fully complies with all requirements and restrictions of state and federal law respecting the employment of undocumented aliens, including, but not limited to, the Immigration Reform and Control Act of 1986, as may be amended from time to time and shall require all subconsultants and sub-subconsultants to comply with the same. Consultant certifies that it has not committed a violation of any such law within the five (5) years immediately preceding the date of execution of this Agreement, and shall not violate any such law at any time during the term of the Agreement.

3.3.10.3 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subconsultant, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. Such non-discrimination shall include, but not be limited to, all activities related to initial employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination. Consultant shall also comply with all relevant provisions of City's Minority Business Enterprise program, Affirmative Action Plan or other related programs or guidelines currently in effect or hereinafter enacted.

3.3.10.4 Air Quality. To the extent applicable, Consultant must fully comply with all applicable laws, rules and regulations in furnishing or using equipment and/or providing services, including, but not limited to, emissions limits and permitting requirements imposed by the South Coast Air Quality Management District (SCAQMD) and/or California Air Resources Board (CARB). Consultant shall indemnify City against any fines or penalties imposed by SCAQMD, CARB, or any other governmental or regulatory agency for violations of applicable laws, rules and/or regulations by Consultant, its subconsultants, or others for whom Consultant is responsible under its indemnity obligations provided for in this Agreement.

3.3.10.5 Water Quality Management and Compliance. Consultant shall keep itself and all subcontractors, staff, and employees fully informed of and in compliance with all local, state and federal laws, rules and regulations that may impact, or be implicated by the performance of the Services including, without limitation, all applicable provisions of the City’s ordinances regulating water quality and storm water; the Federal Water Pollution Control Act (33 U.S.C. § 1251, et seq.); the California Porter-Cologne Water Quality Control Act (Water Code § 13000 et seq.); and any and all regulations, policies, or permits issued pursuant to any such authority. Consultant must additionally comply with the lawful requirements of the City, and any other municipality, drainage district, or other local agency with jurisdiction over the location where the Services are to be conducted, regulating water quality and storm water discharges. City may seek damages from Consultant for delay in completing the Services caused by Consultant’s failure to comply with the laws, regulations and policies described in this Section, or any other relevant water quality law, regulation, or policy.

3.3.10.6 Safety. Consultant shall execute and maintain its work so as to avoid injury or damage to any person or property. In carrying out its Services, the Consultant shall at all times be in compliance with all applicable local, state and federal laws, rules and 865
46700.00100\40935195.1
BB&K (2023) -6- PROFESSIONAL SERVICES AGREEMENT
regulations, and shall exercise all necessary precautions for the safety of employees appropriate to the nature of the work and the conditions under which the work is to be performed.

3.3.11 Insurance.

3.3.11.1 Time for Compliance. Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurance required under this section. Failure to provide and maintain all required insurance shall be grounds for the City to terminate this Agreement for cause.

3.3.11.2 Types of Insurance Required. As a condition precedent to the effectiveness of this Agreement for work to be performed hereunder, and without limiting the indemnity provisions of the Agreement, the Consultant, in partial performance of its obligations under such Agreement, shall procure and maintain in full force and effect during the term of the Agreement the following policies of insurance. If the existing policies do not meet the insurance requirements set forth herein, Consultant agrees to amend, supplement or endorse the policies to do so.
(A) Commercial General Liability: Commercial General Liability Insurance which affords coverage at least as broad as Insurance Services Office "occurrence" form CG 00 01, or the exact equivalent, with limits of not less than $2,000,000 per occurrence and no less than $4,000,000 in the general aggregate. Defense costs shall be paid in addition to the limits. The policy shall contain no endorsements or provisions (1) limiting coverage for contractual liability; (2) excluding coverage for claims or suits by one insured against another (cross-liability); (3) products/completed operations liability; or (4) containing any other exclusion(s) contrary to the terms or purposes of this Agreement. (B) Automobile Liability Insurance: Automobile Liability Insurance with coverage at least as broad as Insurance Services Office Form CA 00 01 covering "Any Auto" (Symbol 1), or the exact equivalent, covering bodily injury and property damage for all activities with limits of not less than $2,000,000 combined limit for each occurrence. (C) Workers' Compensation: Workers' Compensation
Insurance, as required by the State of California and Employer's Liability Insurance with a limit of not less than $1,000,000 per accident for bodily injury and disease. (D) Professional Liability (Errors & Omissions): Professional Liability insurance or Errors & Omissions insurance appropriate to Consultant’s profession with limits of not less than $2,000,000. Covered professional services shall specifically include all work to be performed under the Agreement and delete any exclusions that may potentially affect the work to be performed (for example, any exclusions relating to lead, asbestos, pollution, testing, underground storage tanks, laboratory analysis, soil work, etc.). If coverage is written on a claims-made basis, the retroactive date shall precede the effective date of the initial Agreement and continuous coverage will be maintained or an extended reporting period will be exercised for a period of at least five (5) years from termination or expiration of this Agreement. 866
46700.00100\40935195.1
BB&K (2023) -7- PROFESSIONAL SERVICES AGREEMENT

3.3.11.3 Insurance Endorsements. Required insurance policies shall contain the following provisions, or Consultant shall provide endorsements on forms approved by the City to add the following provisions to the insurance policies:
(A) Commercial General Liability: (1) Additional Insured: The City, its officials, officers, employees, agents, and volunteers shall be additional insureds with regard to liability and defense of suits or claims arising out of the performance of the Agreement.

Additional Insured Endorsements shall not (1) be restricted to "ongoing operations"; (2) exclude "contractual liability"; (3) restrict coverage to "sole" liability of Consultant; or (4) contain any other exclusions contrary to the terms or purposes of this Agreement. For all policies of Commercial General Liability insurance, Consultant shall provide endorsements in the form of ISO CG 20 10 10 01 and 20 37 10 01 (or endorsements providing the exact same coverage) to effectuate this requirement. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (B) Automobile Liability: (1) Additional Insured: The City, its directors, officials, officers, employees, agents, and volunteers shall be covered as additional insureds with respect to the ownership, operation, maintenance, use, loading or unloading of any auto owned, leased, hired or borrowed by the Vendor or for which the Vendor is responsible. (2) Cancellation: Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium.
(C) Professional Liability (Errors & Omissions): (1) Cancellation:

Required insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) This insurance shall be written on a policy form coverage specifically designed to protect against acts, errors or omissions of the Consultant. “Covered Professional Services” as designated in the policy must specifically include work performed under this Agreement. The policy must “pay on behalf of” the insured and include a provision establishing the insurer’s duty to defend.
(D) Workers' Compensation: (1) Cancellation: Required
insurance policies shall not be canceled or the coverage reduced until a thirty (30) day written notice of cancellation has been served upon the City except ten (10) days shall be allowed for non-payment of premium. (2) Waiver of Subrogation: A waiver of subrogation stating that the insurer waives all rights of subrogation against the City, its officials, officers, employees, agents, and volunteers.

3.3.11.4 Primary and Non-Contributing Insurance. All policies of Commercial General Liability and Automobile Liability insurance shall be primary and any other insurance, deductible, or self-insurance maintained by the City, its officials, officers, employees, agents, or volunteers shall not contribute with this primary insurance. Policies shall contain or be endorsed to contain such provisions.

3.3.11.5 Waiver of Subrogation. All required insurance coverages, except for the professional liability coverage, shall contain or be endorsed to waiver of subrogation in favor of the City, its officials, officers, employees, agents, and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these specifications 867
46700.00100\40935195.1
BB&K (2023) -8- PROFESSIONAL SERVICES AGREEMENT
to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants.

3.3.11.6 Deductibles and Self-Insured Retentions. Any deductible or selfinsured retention must be approved in writing by the City and shall protect the City, its officials, officers, employees, agents, and volunteers in the same manner and to the same extent as they would have been protected had the policy or policies not contained a deductible or self-insured retention.

3.3.11.7 Evidence of Insurance. The Consultant, concurrently with the execution of the Agreement, and as a condition precedent to the effectiveness thereof, shall deliver either certified copies of the required policies, or original certificates on forms approved by the City, together with all endorsements affecting each policy. Required insurance policies shall not be in compliance if they include any limiting provision or endorsement that has not been submitted to the City for approval. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf. At least fifteen (15 days) prior to the expiration of any such policy, evidence of insurance showing that such insurance coverage has been renewed or extended shall be filed with the City. If such coverage is cancelled or reduced and not replaced immediately so as to avoid a lapse in the required coverage, Consultant shall, within ten (10) days after receipt of written notice of such cancellation or reduction of coverage, file with the City evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies.

3.3.11.8 Acceptability of Insurers. Each such policy shall be from a company or companies with a current A.M. Best's rating of no less than A:VII and authorized to transact business of insurance in the State of California, or otherwise allowed to place insurance through surplus line brokers under applicable provisions of the California Insurance Code or any federal law.

3.3.11.9 Enforcement of Agreement Provisions (non estoppel).

Consultant acknowledges and agrees that actual or alleged failure on the part of the City to inform Consultant of non-compliance with any requirement imposes no additional obligation on the City nor does it waive any rights hereunder.

3.3.11.10 Requirements Not Limiting. Requirement of specific coverage or minimum limits contained in this Section are not intended as a limitation on coverage, limits, or other requirement, or a waiver of any coverage normally provided by any insurance.

3.3.11.11 Additional Insurance Provisions
(A) The foregoing requirements as to the types and limits of insurance coverage to be maintained by Consultant, and any approval of said insurance by the City, is not intended to and shall not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Consultant pursuant to this Agreement, including but not limited to, the provisions concerning indemnification.
(B) If at any time during the life of the Agreement, any policy of insurance required under this Agreement does not comply with these specifications or is canceled 868
46700.00100\40935195.1
BB&K (2023) -9- PROFESSIONAL SERVICES AGREEMENT
and not replaced, City has the right but not the duty to obtain the insurance it deems necessary and any premium paid by City will be promptly reimbursed by Consultant or City will withhold amounts sufficient to pay premium from Consultant payments. In the alternative, City may cancel this Agreement.
(C) The City may require the Consultant to provide complete copies of all insurance policies in effect for the duration of the Project. (D) Neither the City nor any of its officials, officers, employees, agents or volunteers shall be personally responsible for any liability arising under or by virtue of this Agreement.
(E) The limits set forth herein shall apply separately to each insured against whom claims are made or suits are brought, except with respect to the limits of liability. Further the limits set forth herein shall not be construed to relieve the Consultant from liability in excess of such coverage, nor shall it limit the Consultant’s indemnification obligations to the City and shall not preclude the City from taking such other actions available to the City under other provisions of the Agreement or law.
(F) Consultant shall report to the City, in addition to Consultant’s insurer, any and all insurance claims submitted by Consultant in connection with the Services under this Agreement.

3.3.11.12 Insurance for Subconsultants. Consultant shall include all subconsultants engaged in any work for Consultant relating to this Agreement as additional insureds under the Consultant's policies, or the Consultant shall be responsible for causing subconsultants to purchase the appropriate insurance in compliance with the terms of these Insurance Requirements, including adding the City, its officials, officers, employees, agents, and volunteers as additional insureds to the subconsultant's policies. All policies of Commercial General Liability insurance provided by Consultant’s subconsultants performing work relating to this Agreement shall be endorsed to name the City, its officials, officers, employees, agents and volunteers as additional insureds using endorsement form ISO CG 20 38 04 13 or an endorsement providing equivalent coverage. Consultant shall not allow any subconsultant to commence work on any subcontract relating to this Agreement until it has received satisfactory evidence of subconsultant’s compliance with all insurance requirements under this Agreement, to the extent applicable. The Consultant shall provide satisfactory evidence of compliance with this section upon request of the City.

3.4 Labor Code Requirements.

3.4.1 Prevailing Wages. Consultant is aware of the requirements of California Labor Code Section 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., ("Prevailing Wage Laws"), which require the payment of prevailing wage rates and the performance of other requirements on "public works" and "maintenance" projects. If the Services are being performed as part of an applicable "public works" or "maintenance" project, as defined by the Prevailing Wage Laws, and if the total compensation is $1,000 or more, Consultant agrees to fully comply with such Prevailing Wage Laws. City shall provide Consultant with a copy of the prevailing rates of per diem wages in effect at the commencement of this Agreement. Consultant shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services 869
46700.00100\40935195.1
BB&K (2023) -10- PROFESSIONAL SERVICES AGREEMENT
available to interested parties upon request, and shall post copies at the Consultant's principal place of business and at the project site. It is the intent of the parties to effectuate the requirements of sections 1771, 1774, 1775, 1776, 1777.5, 1813, and 1815 of the Labor Code within this Agreement, and Consultant shall therefore comply with such Labor Code sections to the fullest extent required by law. Consultant shall defend, indemnify and hold the City, its officials, officers, employees, agents, and volunteers free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws.

3.4.2 Registration/DIR Compliance. If the Services are being performed on a public works project of over $25,000 when the project is for construction, alteration, demolition, installation, or repair work, or a public works project of over $15,000 when the project is for maintenance work, in addition to the foregoing, then pursuant to Labor Code sections 1725.5 and 1771.1, the Consultant and all subconsultants must be registered with the Department of Industrial Relations (“DIR”). Consultant shall maintain registration for the duration of the Project and require the same of any subconsultants.

3.4.3 Compliance Monitoring. This Project may also be subject to compliance monitoring and enforcement by the DIR. It shall be Consultant’s sole responsibility to comply with all applicable registration and labor compliance requirements, including the submission of payroll records directly to the DIR. Any stop orders issued by the DIR against Consultant or any subconsultant that affect Consultant’s performance of services, including any delay, shall be Consultant’s sole responsibility. Any delay arising out of or resulting from such stop orders shall be considered Consultant caused delay and shall not be compensable by the City. Consultant shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claim or liability arising out of stop orders issued by the DIR against Consultant or any subconsultant.

3.4.4 Labor Certification. By its signature hereunder, Consultant certifies that it is aware of the provisions of Section 3700 of the California Labor Code which require every employer to be insured against liability for Worker's Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services.

3.5 Termination of Agreement.

3.5.1.1 Grounds for Termination. City may, by written notice to Consultant, terminate the whole or any part of this Agreement at any time and without cause by giving written notice to Consultant of such termination, and specifying the effective date thereof, at least seven (7) days before the effective date of such termination. Upon termination, Consultant shall be compensated only for those Services which have been adequately rendered to City, and Consultant shall be entitled to no further compensation. Consultant may not terminate this Agreement except for cause. The rights and remedies of the City provided in this section shall not be exclusive and are in addition to any other rights and remedies provided by law, equity or under this Agreement.

3.5.1.2 Effect of Termination. If this Agreement is terminated as provided herein, City may require Consultant to provide all finished or unfinished Documents and Data and other information of any kind prepared by Consultant in connection with the performance of Services under this Agreement. Consultant shall be required to provide such document and other information within fifteen (15) days of the request. 870
46700.00100\40935195.1
BB&K (2023) -11- PROFESSIONAL SERVICES AGREEMENT

3.5.1.3 Additional Services. In the event this Agreement is terminated in whole or in part as provided herein, City may procure, upon such terms and in such manner as it may determine appropriate, services similar to those terminated.

3.6 Indemnification.

3.6.1 To the fullest extent permitted by law, Consultant shall defend (with counsel of City’s choosing), indemnify and hold the City, its officials, officers, employees, volunteers, and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct of Consultant, its officials, officers, employees, subcontractors, consultants or agents in connection with the performance of the Consultant’s Services, the Project or this Agreement, including without limitation the payment of all damages, expert witness fees and attorney’s fees and other related costs and expenses except such loss or damage caused by the sole negligence or willful misconduct of the City. Consultant's obligation to indemnify shall survive expiration or termination of this Agreement and shall not be restricted to insurance proceeds, if any, received by Consultant, the City, its officials, officers, employees, agents, or volunteers.

3.6.2 If Consultant’s obligation to defend, indemnify, and/or hold harmless arises out of Consultant’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Consultant’s indemnification obligation shall be limited to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Consultant, and, upon Consultant obtaining a final adjudication by a court of competent jurisdiction, Consultant’s liability for such claim, including the cost to defend, shall not exceed the Consultant’s proportionate percentage of fault.

3.7 General Provisions.

3.7.1 Accounting Records. Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to this Agreement. Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement.

3.7.2 Independent Contractors and Subcontracting.

3.7.2.1 Use of Consultants. Consultant is aware of statutory and case law regarding classification of workers as independent contractors, including California Labor Code Section 2750.3 and Dynamex Operations West, Inc. v. Superior Court, 4 Cal. 5th 903 (2018). To ensure that Consultant is in compliance with the California Labor Code, Consultant shall only utilize its employees to provide the Services. Consultant may not provide the services through any independent contractor, subcontractor or subconsultant (“Subcontractor(s)”) unless approved by the City as set forth in Section 3.7.2.2 below. Consultant represents and warrants that all personnel who perform the Services on Consultant’s behalf are Consultant’s employees, and that Consultant complies with all applicable laws, rules and regulations governing its 871
46700.00100\40935195.1
BB&K (2023) -12- PROFESSIONAL SERVICES AGREEMENT
employees, including, but not limited to, the California Labor Code, Unemployment Insurance Code and all applicable Industrial Welfare Commission Wage Orders.

3.7.2.2 Prior Approval Required. Consultant shall not use any Subcontractor to provide the Services, or any portion of the work required by this Agreement, without prior written approval of City. In the event that City authorizes Consultant to use a Subcontractor, Consultant shall enter into a written agreement with the Subcontractor, which must include all provisions of the Agreement, including a restriction on the Subcontractor’s use of further independent contractors, subcontractors or subconsultants without the City’s prior written consent.

3.7.3 Delivery of Notices. All notices permitted or required under this Agreement shall be given to the respective parties at the following address, or at such other address as the respective parties may provide in writing for this purpose:

Consultant: AKM Consulting Engineers
553 Wald
Irvine, CA 92618
ATTN: Diann Pay, P.E., Project Manager
City: City of Ontario
303 East “B” Street
Ontario, CA 91764
ATTN: Dennis Mejia, P.E., Utilities Engineering Division Manager
With Copy To: City of Ontario
303 East “B” Street
Ontario, CA 91764
ATTN: Records Management
Such notice shall be deemed made when personally delivered or when mailed, forty-eight (48) hours after deposit in the U.S. Mail, first class postage prepaid and addressed to the party at its applicable address. Actual notice shall be deemed adequate notice on the date actual notice occurred, regardless of the method of service.

3.7.4 Ownership of Materials and Confidentiality.

3.7.4.1 Documents & Data; Licensing of Intellectual Property. This Agreement creates a non-exclusive and perpetual license for City to copy, use, modify, reuse, or sublicense any and all copyrights, designs, and other intellectual property embodied in plans, specifications, studies, drawings, estimates, and other documents or works of authorship fixed in any tangible medium of expression, including but not limited to, physical drawings or data magnetically or otherwise recorded on computer diskettes, which are prepared or caused to be prepared by Consultant under this Agreement ("Documents & Data"). All Documents & Data shall be and remain the property of City, and shall not be used in whole or in substantial part by Consultant on other projects without the City’s express written permission. Within thirty (30) days following the completion, suspension, abandonment or termination of this Agreement, Consultant shall provide to City reproducible copies of all Documents & Data, in a form and amount required by City. City reserves the right to select the method of document reproduction and to establish 872
46700.00100\40935195.1
BB&K (2023) -13- PROFESSIONAL SERVICES AGREEMENT
where the reproduction will be accomplished. The reproduction expense shall be borne by City at the actual cost of duplication. In the event of a dispute regarding the amount of compensation to which the Consultant is entitled under the termination provisions of this Agreement, Consultant shall provide all Documents & Data to City upon payment of the undisputed amount. Consultant shall have no right to retain or fail to provide to City any such documents pending resolution of the dispute. In addition, Consultant shall retain copies of all Documents & Data on file for a minimum of fifteen (15) years following completion of the Project, and shall make copies available to City upon the payment of actual reasonable duplication costs. Before destroying the Documents & Data following this retention period, Consultant shall make a reasonable effort to notify City and provide City with the opportunity to obtain the documents.

3.7.4.2 Subconsultants. Consultant shall require all subconsultants to agree in writing that City is granted a non-exclusive and perpetual license for any Documents & Data the subconsultant prepares under this Agreement. Consultant represents and warrants that Consultant has the legal right to license any and all Documents & Data. Consultant makes no such representation and warranty in regard to Documents & Data which were prepared by design professionals other than Consultant or its subconsultants, or those provided to Consultant by the City.

3.7.4.3 Right to Use. City shall not be limited in any way in its use or reuse of the Documents and Data or any part of them at any time for purposes of this Project or another project, provided that any such use not within the purposes intended by this Agreement or on a project other than this Project without employing the services of Consultant shall be at City’s sole risk. If City uses or reuses the Documents & Data on any project other than this Project, it shall remove the Consultant’s seal from the Documents & Data and indemnify and hold harmless Consultant and its officers, directors, agents and employees from claims arising out of the negligent use or re-use of the Documents & Data on such other project. Consultant shall be responsible and liable for its Documents & Data, pursuant to the terms of this Agreement, only with respect to the condition of the Documents & Data at the time they are provided to the City upon completion, suspension, abandonment or termination. Consultant shall not be responsible or liable for any revisions to the Documents & Data made by any party other than Consultant, a party for whom the Consultant is legally responsible or liable, or anyone approved by the Consultant.

3.7.4.4 Indemnification. Consultant shall defend, indemnify and hold the City, its directors, officials, officers, employees, volunteers and agents free and harmless, pursuant to the indemnification provisions of this Agreement, for any alleged infringement of any patent, copyright, trade secret, trade name, trademark, or any other proprietary right of any person or entity in consequence of the use on the Project by City of the Documents & Data, including any method, process, product, or concept specified or depicted.

3.7.4.5 Confidentiality. All ideas, memoranda, specifications, plans, procedures, drawings, descriptions, computer program data, input record data, written information, and other Documents & Data either created by or provided to Consultant in connection with the performance of this Agreement shall be held confidential by Consultant. Such materials shall not, without the prior written consent of City, be used by Consultant for any purposes other than the performance of the Services. Nor shall such materials be disclosed to any person or entity not connected with the performance of the Services or the Project. Nothing furnished to Consultant which is otherwise known to Consultant or is generally known, or has become known, to the related industry shall be deemed confidential. Consultant shall not use 873
46700.00100\40935195.1
BB&K (2023) -14- PROFESSIONAL SERVICES AGREEMENT
City's name or insignia, photographs of the Project, or any publicity pertaining to the Services or the Project in any magazine, trade paper, newspaper, television or radio production or other similar medium without the prior written consent of City.

3.7.4.6 Confidential Information. The City shall refrain from releasing Consultant’s proprietary information ("Proprietary Information") unless the City's legal counsel determines that the release of the Proprietary Information is required by the California Public Records Act or other applicable state or federal law, or order of a court of competent jurisdiction, in which case the City shall notify Consultant of its intention to release Proprietary Information.

Consultant shall have five (5) working days after receipt of the release notice to give City written notice of Consultant's objection to the City's release of Proprietary Information. Consultant shall indemnify, defend and hold harmless the City, and its officers, directors, employees, and agents from and against all liability, loss, cost or expense (including attorney’s fees) arising out of a legal action brought to compel the release of Proprietary Information. City shall not release the Proprietary Information after receipt of an objection notice unless either: (1) Consultant fails to fully indemnify, defend (with City's choice of legal counsel), and hold City harmless from any legal action brought to compel such release; and/or (2) a final and non-appealable order by a court of competent jurisdiction requires that City release such information.

3.7.5 Cooperation; Further Acts. The Parties shall fully cooperate with one another, and shall take any additional acts or sign any additional documents as may be necessary, appropriate or convenient to attain the purposes of this Agreement.

3.7.6 Entire Agreement. This Agreement contains the entire agreement of the Parties with respect to the subject matter hereof, and supersedes all prior negotiations, understandings or agreements.

3.7.7 Attorneys’ Fees. If either party commences an action against the other party, either legal, administrative or otherwise, arising out of or in connection with this Agreement, the prevailing party in such litigation shall be entitled to have and recover from the losing party reasonable attorneys’ fees and all costs of such action.

3.7.8 Governing Law. This Agreement shall be governed by the laws of the State of California. Venue shall be in San Bernardino County. In addition to any and all contract requirements pertaining to notices of and requests for compensation or payment for extra work, disputed work, claims and/or changed conditions, Consultant must comply with the claim procedures set forth in Government Code sections 900 et seq. prior to filing any lawsuit against the City. Such Government Code claims and any subsequent lawsuit based upon the Government Code claims shall be limited to those matters that remain unresolved after all procedures pertaining to extra work, disputed work, claims, and/or changed conditions have been followed by Consultant. If no such Government Code claim is submitted, or if any prerequisite contractual requirements are not otherwise satisfied as specified herein, Consultant shall be barred from bringing and maintaining a valid lawsuit against the City.

3.7.9 Time of Essence. Time is of the essence for each and every provision of this Agreement.

3.7.10 City's Right to Employ Other Consultants. City reserves right to employ other consultants in connection with this Project.
874
46700.00100\40935195.1
BB&K (2023) -15- PROFESSIONAL SERVICES AGREEMENT

3.7.11 Successors and Assigns. This Agreement shall be binding on the successors and assigns of the parties.

3.7.12 Assignment or Transfer. Consultant shall not assign, sublet, or transfer this Agreement or any rights under or interest in this Agreement without the written consent of the City, which may be withheld for any reason. Any attempt to so assign or so transfer without such consent shall be void and without legal effect and shall constitute grounds for termination.

Consultant shall not subcontract any portion of the Services required by this Agreement, except as expressly stated herein, without prior written approval of City. Subcontracts, if any, shall contain a provision making them subject to all provisions stipulated in this Agreement.

3.7.13 Construction; References; Captions. Since the Parties or their agents have participated fully in the preparation of this Agreement, the language of this Agreement shall be construed simply, according to its fair meaning, and not strictly for or against any Party. Any term referencing time, days or period for performance shall be deemed calendar days and not work days. All references to Consultant include all personnel, employees, agents, and subconsultants of Consultant, except as otherwise specified in this Agreement. All references to City include its elected officials, officers, employees, agents, and volunteers except as otherwise specified in this Agreement. The captions of the various articles and paragraphs are for convenience and ease of reference only, and do not define, limit, augment, or describe the scope, content, or intent of this Agreement.

3.7.14 Amendment; Modification. No supplement, modification, or amendment of this Agreement shall be binding unless executed in writing and signed by both Parties.

3.7.15 Waiver. No waiver of any default shall constitute a waiver of any other default or breach, whether of the same or other covenant or condition. No waiver, benefit, privilege, or service voluntarily given or performed by a Party shall give the other Party any contractual rights by custom, estoppel, or otherwise.

3.7.16 No Third-Party Beneficiaries. There are no intended third party beneficiaries of any right or obligation assumed by the Parties.

3.7.17 Invalidity; Severability. If any portion of this Agreement is declared invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect.

3.7.18 Prohibited Interests. Consultant maintains and warrants that it has not employed nor retained any company or person, other than a bona fide employee working solely for Consultant, to solicit or secure this Agreement. Consultant warrants that it has not paid nor has it agreed to pay any company or person, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, brokerage fee, gift or other consideration contingent upon or resulting from the award or making of this Agreement. Consultant further agrees to file, or shall cause its employees or subconsultants to file, a Statement of Economic Interest with the City’s Filing Officer as required under state law in the performance of the Services. For breach or violation of this warranty, City shall have the right to rescind this Agreement without liability. For the term of this Agreement, no member, officer or employee of City, during the term of his or her service with City, shall have any direct interest in this Agreement, or obtain any present or anticipated material benefit arising therefrom. 875
46700.00100\40935195.1
BB&K (2023) -16- PROFESSIONAL SERVICES AGREEMENT

3.7.19 Authority to Enter Agreement. Consultant has all requisite power and authority to conduct its business and to execute, deliver, and perform the Agreement. Each Party warrants that the individuals who have signed this Agreement have the legal power, right, and authority to make this Agreement and bind each respective Party.

3.7.20 Counterparts. This Agreement may be signed in counterparts, each of which shall constitute an original.

3.7.21 Survival. All rights and obligations hereunder that by their nature are to continue after any expiration or termination of this Agreement, including, but not limited to, the indemnification obligations, shall survive any such expiration or termination.

SIGNATURES ON NEXT PAGE
876
46700.00100\40935195.1
BB&K (2023) -17- PROFESSIONAL SERVICES AGREEMENT

SIGNATURE PAGE TO PROFESSIONAL SERVICES AGREEMENT

BETWEEN THE CITY OF ONTARIO AND
AKM Consulting Engineers
IN WITNESS WHEREOF, each of the Parties has caused this Agreement to be executed on the day and year first above written.

CITY OF ONTARIO AKM CONSULTING ENGINEERS
By: AAA
Its: BBB
Printed Name: CCC
By: DDD
Its: EEE
Printed Name: FFF
[If Corporation, TWO SIGNATURES,
President OR Vice President AND Secretary
OR Treasurer REQUIRED]
Approved By:

Scott Ochoa
City Manager
Approved as to Form:
_____________________________________
Best Best & Krieger LLP
City Attorney
Attested By:

City Clerk
877
46700.00100\40935195.1
BB&K (2023) Exhibit “A”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "A"

SCOPE OF SERVICES
878
46700.00100\40935195.1
BB&K (2023) Exhibit “B”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "B"

SCHEDULE OF SERVICES
879
46700.00100\40935195.1
BB&K (2023) Exhibit “C”-1 PROFESSIONAL SERVICES AGREEMENT EXHIBIT "C"

COMPENSATION
880
Department: Economic Development
Prepared By: Karen Khukoyan
Staff Member Presenting:

Jennifer McLain Hiramoto, Economic
Development Director
Approved By:

Submitted To: Council/OHA
Approved: _______________________________
Continued To: ___________________________
Denied: __________________________________
Item No: 20
SUBJECT: AN AMENDMENT TO THE DESIGN SERVICES AGREEMENT WITH RJM DESIGN

GROUP FOR ON-CALL LANDSCAPE ARCHITECTURAL SERVICES FOR THE ONTARIO

MILLS LANDSCAPE DESIGN

CITY OF ONTARIO
Agenda Report
November 21, 2023
SECTION:

CONSENT CALENDAR
RECOMMENDATION: That the City Council authorize the City Manager or his designee to execute Amendment No. 5 to the Design Services Agreement for contract No. PM 1819-1 with RJM Design Group of San Juan Capistrano, California, to provide On-Call Landscape Architectural Services for the Ontario Mills Landscape Design Project in a total amount of $102,100 and a total not-to-exceed amount of $527,100.

THE FOLLOWING COUNCIL GOALS ARE BEING ACHIEVED:

Invest in the Growth and Evolution of the City's Economy Focus Resources in Ontario's Commercial and Residential Neighborhoods Operate in a Businesslike Manner
FISCAL IMPACT: The FY 2023-24 Adopted Budget includes appropriations in the General Fund for On-Call Landscape Architectural Services for the Ontario Mills Project. If additional appropriations are needed, they will be included on the next quarterly budget update. The recommended Amendment in the amount of $102,100 will increase the current total not-to-exceed amount to $527,100.

BACKGROUND & ANALYSIS: The Ontario Mills (the "Mills"), a Simon Center, is one of the largest outlet and retail shopping malls in California, and continues to be an important economic engine in the Inland Empire. It is responsible for the employment of hundreds of employees at its nearly 200 stores, generates a significant amount of sales tax revenue to the City of Ontario, and is a notable tourist attraction - so much so that one of the tenants in the mall is the California Welcome Center, sponsored by Visit California.

While nearly 28 million visitors continue to flock to the mall each year, and private development continues in the commercial district surrounding the Ontario Mills, the exterior of the Ontario Mills is dated and does not reflect the mall's prominence. Given its economic development importance, the City is exploring a partnership with the Ontario Mills on a proposed landscape design project 881
that will modernize the look of the landscaping and ultimately enhance the aesthetics of the exterior of the Mills.

In an effort to beautify the entries and make the exterior more comfortable to visitors and future businesses, the City is recommending amending the contract by an additional $102,000 with existing on-call vendor, RJM Design Group.

RJM Design Group will prepare conceptual landscaping plans for three (3) different entries of the shopping complex.

1. Fashion District Entry – South side of Ontario Mills, facing Ontario Mills Parkway.

2. Rotunda Entry – Northeast side facing Rochester & Ontario Mills Drive.

3. Market Broiler/AMC Entry – North side facing Franklin Avenue & Fourth Street.

Should the City and the Mills agree on these designs, construction documents will be prepared. 882
883
884
885
886
887
888
889
890
891
892
893
Department: Planning
Prepared By: Alexis Vaughn
Staff Member Presenting:

Scott Murphy, Executive Director Community
Development
Reviewed By: Edmelynne V Hutter, Kimberly
Ruddins, Rudy Zeledon
Approved By:

Submitted To: Council/OHA
Approved: _______________________________
Continued To: ___________________________
Denied: __________________________________
Item No: 21
SUBJECT: A PUBLIC HEARING TO CONSIDER AN ADDENDUM TO THE ONTARIO PLAN 2050

SUPPLEMENTAL ENVIRONMENTAL IMPACT REPORT AND AN AMENDMENT TO THE CALIFORNIA COMMERCE CENTER SPECIFIC PLAN (FILE NO. PSPA22-006)

CITY OF ONTARIO
Agenda Report
November 21, 2023
SECTION:

PUBLIC HEARINGS
RECOMMENDATION: That the City Council consider and adopt:

A. A Resolution approving an Addendum to The Ontario Plan 2050 Supplemental Environmental Impact Report for File No. PSPA22-006; and
B. A Resolution approving File No. PSPA22-006, amending the California Commerce Center Specific Plan to change the land use designation from Commercial/Food/Hotel to Light Industrial, update exhibits and text to support the change, and bring the Specific Plan into compliance with The Ontario Plan 2050 (General Plan) for 16.65 acres of land located at the southwest corner of Rockefeller Avenue and Wanamaker Avenue.

THE FOLLOWING COUNCIL GOALS ARE BEING ACHIEVED:

Invest in the Growth and Evolution of the City's Economy Operate in a Businesslike Manner
FISCAL IMPACT: There is not a direct fiscal impact associated with this action.

BACKGROUND & ANALYSIS: On July 18, 2022, the Applicant submitted an amendment to the California Commerce Center Specific Plan (File No. PSPA22-006), Tentative Parcel Map No. 20559 (File No. PMTT22-025), and Development Plan (File No. PDEV22-034) applications to demolish existing commercial buildings and construct one industrial building totaling 344,110 square feet.

The Amendment to the California Commerce Center Specific Plan proposes to modify the land use designation on the Project site, a 16.65-acre piece of land located at the southeast corner of Rockefeller Avenue and Wanamaker Avenue, from Commercial/Food/Hotel to Light Industrial. The Amendment will bring the property into compliance with The Ontario Plan (TOP) 2050’s Land Use Plan, which designates the property as Industrial (0.55 Floor Area Ratio (FAR)). The Amendment also 894
includes exhibit and text modifications to support the Amendment. The document has been appended to the Resolution for the Specific Plan Amendment as Attachment A.

The Project site and the surrounding properties have been zoned for industrial and commercial development since the California Commerce Center Specific Plan (Specific Plan) was established in January of 1983. The Project site is currently developed with a new and used car dealership (Citrus Motors, including Citrus Kia and Citrus Ford). Daily operations include retail sales and motor vehicle servicing activities, including a wash bay and paint booth. The dealership facilities have a combined 161,320 square feet of commercial floor area, which translates to a Floor Area Ratio (FAR) of 0.22.

The dealership will be relocated to a new site at the northeast corner of Haven Avenue and Guasti Road (adjacent to the Mercedes dealership).

According to the Economic and Fiscal Impact Analysis by Andrew Chang and Company, Inc., dated August 30, 2023, the proposed industrial building facilitated by the Specific Plan Amendment is expected to be occupied by 2025, and to inject approximately $265 million of direct spend into the City of Ontario from 2024 to 2028. The estimated costs for development are calculated to be approximately $27 million, exclusive of development fees, to be borne by the Applicant. The additional direct spend from the Project is expected to stimulate economic activity and generate 275 Full-Time Equivalent (FTE) jobs annually in the city. The Project is also expected to generate approximately $60 million in personal earnings produced within Ontario from 2024 to 2028 ($15 million annually, once full-scale operations begin). The Project will increase economic output in Ontario by approximately $309 million from 2024 to 2028, and $80 million of economic output annually once fully operational, which equates to $8.3 million in tax collections (property and sales tax) and development fees cumulatively through 2028 and an average of over $1.7 million in total taxes and fees to Ontario’s General Fund on a consistent annual basis. Lastly, there is no anticipated loss in sales tax revenues from the current occupant of the site, Citrus Motors, as the dealership will remain within the City.

ENVIRONMENTAL REVIEW: An Addendum to TOP 2050 Supplemental Environmental Impact Report (State Clearinghouse No. 2021070364, certified by the Ontario City Council on August 16, 2022, in conjunction with File No. PGPA20-002) was prepared for this Project. File No. PGPA20-002 established the underlying TOP 2050 (General Plan) Land Use Plan designation of Industrial (IND,

0.55 FAR) on the Project site. The related Specific Plan Amendment will bring the Project site into compliance with TOP 2050 Land Use Plan. The Addendum prepared for the Project does not preclude the imposition of any mitigation measures as laid forth in TOP 2050 SEIR and said mitigation measures are included by reference in the Project conditions of approval. The Addendum also included studies and assessments to support the findings that the Project will not have a significant environmental affect not already covered by TOP 2050 SEIR.

PLANNING COMMISSION REVIEW: On October 24, 2023, the Planning Commission approved the related Tentative Parcel Map and Development Plan applications and voted to recommend City Council approval of the use of the Addendum along with the Amendment to the California Commerce Center Specific Plan. Prior to the Planning Commission hearing, the City received a letter of support for the project from Mitchell M. Tsai, Attorney at Law., representing Southwest Mountain States Regional Council of Carpenters.
895
Case Planner: Alexis Vaughn Hearing Body Date Decision Action Planning Director
Approval:

DAB 09/18/2023 Approval Recommend
PC 10/24/2023
Recommend,
Final (PMTT22-006,
PDEV22-034)
Submittal Date: 07/18/2022 CC TBD Final (PSPA22-006)
FILE NOS: PSPA22-006, PMTT22-025 (TPM 20559) and PDEV22-034 SUBJECT: A public hearing to consider the following: [1] An amendment to the California Commerce Center Specific Plan (File No. PSPA22-006), to change the land use designation from Commercial/Food/Hotel to Light Industrial, update exhibits and text to support the change, and bring the Specific Plan into conformance with Industrial (0.55 FAR) land use designation of The Ontario Plan 2050 Policy Plan (General Plan); [2] A Tentative Parcel Map (File No. PMTT22-025, TPM 20559) to consolidate two existing parcels into one; and [3] A Development Plan (File No. PDEV22-034) to raze approximately 161,320 square feet of commercial buildings and construct one 344,110 square-foot industrial building, on 16.65 acres of land generally located at the southeast corner of Rockefeller Avenue and Wanamaker Avenue, at 1350 and 1375 S. Woodruff Way, within the proposed Light Industrial Land Use Designation of the California Commerce Center Specific Plan; (APNs: 0238-201-41 and 0238-221-22). Submitted by Link Logistics Real Estate Management LLC. City Council action is required for File No. PSPA22-006.

PROPERTY OWNER: B9 Wanamaker Owner LLC
RECOMMENDED ACTION: That
the Planning Commission: [1]
consider and recommend the
City Council approve the use of
an Addendum to The Ontario
Plan 2050 (“TOP 2050”) Certified
Supplemental Environmental
Impact Report (“SEIR”); [2]
consider and recommend the
City Council approve an
amendment to the California
Commerce Center Specific Plan
(File No. PSPA22-006); and [3]
consider and approve File Nos.

PMTT22-025 (TPM 20559) and
PDEV22-036, pursuant to the
facts and reasons contained in
the staff report and attached Figure 1: Project Location 303 East B Street, Ontario, California 91764 Phone: 909.395.2036 / Fax: 909.395.2420

PLANNING COMMISSION

AGENDA REPORT
October 24, 2023
896
Planning Commission Agenda Report
File Nos.: PSPA22-006, PMTT22-025 (TPM 20559) and PDEV22-034 October 24, 2023