Agenda packet — Roseville City Council, April 2, 2025 (part 4 of 6)

¤ COPYRIGHT, 2020, GE PACKAGED POWER, L.P.,ALL RIGHTS RESERVED. THIS DRAWING IS THE PROPRIETARY AND/OR CONFIDENTIAL PROPERTY OF GE PACKAGED POWER, L.P., AND IS LOANED IN STRICT CONFIDENCE WITH THE UNDERSTANDING THAT IT WILL NOT BE REPRODUCED NOR USED FOR ANY PURPOSE EXCEPT THAT FOR WHICH IT IS LOANED. IT SHALL BE IMMEDIATELY RETURNED ON DEMAND, AND IS SUBJECT TO ALL OTHER TERMS AND CONDITIONS OF ANY WRITTEN AGREEMENT OR PURCHASE ORDER WHICH INCORPORATES OR RELATES TO THIS DRAWING.

LM2X/TM2500 5-8-10 Minute Starts
Introduction
The
GE AE LM2X/TM2500 (LM2500, +, G4) packages have the unique ability to reach full power from a cold start within 8 minutes, as standard offering with no impact to life.

An 8-minute start cycle is significant since many power pools allow spinning reserve credit. The LM2X/TM2500 fast start capability is unique in that it does not increase maintenance costs or intervals. The operating flexibility of the utility grid will be greatly enhanced and the overall system production costs will be substantially lower.

A 5-minute start is also offered, as an option. This 5-minute start feature has a slight life estimated hit to the HPT rotor shaft on a LM2500+G4 engine with reduction in start attempts to 4000 total base. The LM2500+ engine has no impact to life and follows current O&M procedures.

Unlike turbo machinery using solid forgings and thick wall castings, the LM2500 gas turbine sections are designed as flight engine type, allowing a high tolerance to cyclic duty. Its lightweight design (rotor and castings are constructed of thin-wall, high- strength alloy materials) allows it to operate efficiently under high thermal stress gradients and concentrations. This design effort has dramatically increased low-cycle fatigue life.

Instrumentation and Components
Special provisions have been designed for the engine and its package auxiliaries to accommodate fast start capability.

There are no restrictions for 5-8-10 minute fast start for LM2X Gas Fuel SAC or DLE , or Liquid Fuel DF1, DF2, SAC applications. For Liquid Fuel DLE applications there are GT Package and customer supplied provisions required, as listed below this paper.

1. Enclosure Purging – Turbine enclosure air purging is initiated before the exhaus t
system
purge and the acceleration to HP core idle sequences begin. At least 1X air change
s are typically processed to the enclosure.

2. Be
aring Lubrication Systems – AC lube oil pumps and backup DC lube oil pumps lu
bricate (as applicable) Gearbox and Generator bearings. During the star
t up sequence the AC lube oil pump supplies lubricant oil to the bearings. In the even
t of loss of AC power, the DC lube oil system or run down lube oil tanks, as app
licable, operate as backup. For LM2X units with rundown tanks, as applicable, the AC lube oil pump can be operated continuously when the unit is at rest, to GE
Power Aero
Position Paper #157
Rev A
Date June 1, 2020
16415 Jacintoport Blvd
Houston, TX 77015
USA
T 001-832-954-1309
For Information Only
PP157 Rev A

Page 2 of 7 ends

3. Liquid Fuel Inlet Temperature – For LM2X/TM2500 Liquid Fuel DLE applications, the liquid fuel inlet supply temperature at the GT package must be above 100 deg F prior to light-off. GE supplied liquid fuel boost skid consists of liquid fuel high pressure pump and inlet heater to ensure proper fuel temperature. In addition, the customer supplied liquid fuel interconnect piping supply and return from the boost skid to main package must be heat traced to maintain fuel temperature 70 deg F, +/- 10 deg F. For 5-minute start applications, customer supplied liquid fuel piping from liquid fuel forwarding pump to GE liquid fuel boost skid must be heat traced to maintain fuel temperature 90 deg F, +/- 10 deg F. This would ensure that the liquid furl is at proper temperature for 5, 8-minute start feature.

4. Gas Turbine Exhaust System and Stack (Simple Cycle) – Exhaust system volume of exhaust duct to the Stack should be limited, as much as possible and ensure no long horizontal sections are installed. This would ensure short purge time as possible for ability to reach 5-minute start profile. If a Horizontal exhaust section is utilized GT Purge credit in accordance with NFPA 85, latest revision, may be required to achieve a 5-minute start (considered conservative for Simple Cycle application).

5. Fuel System Valve Bottle Test – In accordance to local AHJ (Authority Having Jurisdiction) there may be project specific requirements for Valve Proving tests, prior to start and ignition. The time to complete Valve Proving Tests is NOT included in the standard 5-minute start time profile. In accordance to some local AHJ (i.e. Australia, New Zealand) entities, there could be opportunity to supplement pressure plug in the fuel system bottle via inert gas medium. This would eliminate the requirement for Valve Proving prior to start up and ignition (considered conservative for Simple Cycle application).

6. The gas turbine warm-up timer is set for 60-seconds - During this 60-second warm-up timer the generator can be synchronized to utility grid and gas turbine would ramp to minimum load. Following completion of warm up timer the gas turbine could be ramped to full load.

LM2X/TM2500 System Control Start Sequences
Table 1 depicts the Optional 5-minute fast start schedule sequence and duration of each event. Figure 1 depicts the 5-minute start up procedure in graphic format for this application.

For Information Only
PP157 Rev A

Page 3 of 7 ends

Table 2 depicts the 8-minute fast start schedule sequence and duration of each event. Figure 2 depicts the 8-minute start up procedure in graphic format for this application.

Table 3 depicts the 10-minute fast start schedule sequence and duration of each event. Figure 3 depicts the 10-minute start up procedure in graphic format for this application.

The engine purge times in the following Tables apply to exhaust systems that terminate to standard exhaust stack or connect to systems with a (SCR) Selective Catalytic Reduction Unit or Heat Recovery Steam Generator that is continually purged by a forced air purging system or has been pre-purged with GT Purge Credit in accordance to NFPA 85 and GEP guidelines.

For Information Only
For Information Only
For Information Only
For Information Only
For Information Only
For Information Only
For Information Only
For Information Only
For Information Only
PP29 Rev C

Page 1 of 4 ends

¤ COPYRIGHT, 2018, GE PACKAGED POWER, L.P.,ALL RIGHTS RESERVED. THIS DRAWING IS THE PROPRIETARY AND/OR CONFIDENTIAL PROPERTY O F GE PACKAGED POWER, L.P., AND IS LOANED IN STRICT CONFIDENCE WITH THE UNDERSTANDING THAT IT WILL NOT BE REPRODUCED NOR USED FOR ANY PURPOSE EXCEPT THAT FOR WHICH IT IS LOANED. IT SHALL BE IMMEDIATELY RETURNED ON DEMAND, AND IS SUBJECT TO ALL OTHER TERMS AND CONDITIO NS OF ANY WRITTEN AGREEMENT OR PURCHASE ORDER WHICH INCORPORATES OR RELATES TO THIS DRAWING.

TM2500 GT Engine Purge Times
Introduction
The purpose of the position paper is to describe GE Power requirements for purging of the TM2500 mobile power generation plant’s turbine exhaust system.

Description - General Reference
Standard Exhaust System, Simple Cycle: NFPA 37 Non-Standard Exhaust System with HRSG and/or SCR: NFPA 85 (Combined Cycle Application)
Standard Exhaust System – Simple Cycle
The standard TM2500 start cycle, includes a 30 second crank/purge of the engine and exhaust system produces a total exchange volume greater than the minimum 1X air exchanges in compliance to NFPA 37 referenced section. At the crank/purge cycle speed of 2400 RPM, the TM2500 engine airflow rate is 8167 SCFM. This total flow using the standard 30 second time duration results in at least 6 air exchanges through the turbine and exhaust system assembly.

Non-Standard Exhaust Systems – Combined Cycle
The gas turbine exhaust systems equipped as described in referenced section of NFPA 85, represent non-standard TM2500 applications (see nonstandard typical exhaust system examples below).

HRSG and/or SCR
TM2500 applications that do have both the standard exhaust system trailer and a HRSG and/or SCR, that is Combined Cycle Application, the exhaust system HRSG and/or SCR section(s) must be purged with at least 5 air changes, 5 minutes minimum before firing the engine in accordance to NFPA 85.

For these TM2500 applications, the pre-start exhaust purge time must be determined by calculation of the total volume to be purged and the resultant value of the required purge time entered into the control systems. With respect to the purge of combined cycle exhaust system, the volume that is to be purged per NFPA 85 is between the GE
Power Aero
Position Paper #29
Rev C
Date April 1, 2018
16415 Jacintoport Blvd
Houston, TX 77015
USA
T 001-832-954-1309
For Information Only
PP29 Rev C

Page 2 of 4 ends

¤ COPYRIGHT, 2018, GE PACKAGED POWER, L.P.,ALL RIGHTS RESERVED. THIS DRAWING IS THE PROPRIETARY AND/OR CONFIDENTIAL PROPERTY OF GE PACKAGED POWER, L.P., AND IS LOANED IN STRICT CONFIDENCE WITH THE UNDERSTANDING THAT IT WILL NOT BE REPRODUCED NOR USED FOR ANY PURPOSE EXCEPT THAT FOR WHICH IT IS LOANED. IT SHALL BE IMMEDIATELY RETURNED ON DEMAND, AND IS SUBJECT TO ALL OTHER TERMS AND CONDITIONS OF ANY WRITTEN AGREEMENT OR PURCHASE ORDER WHICH INCORPORATES OR RELATES TO THIS DRAWING. outlet of the gas turbine to the outlet of HRSG super heater and/or the entire SCR system.

To reduce the risk of unburned fuels entering the gas turbine engine / exhaust system when off line, GE Energy has incorporated safety design features in accordance to NFPA 85 release to grant GT Purge Credit.

Gas Fuel System
Gas fuel system is incorporated with three block valves, with proof of closure, in series with two automatic vent valves connected in between these valves (triple block and double vent valve system).
1) GT Purge Credit allowed following Normal Shutdown, non-related to fuel system or ESD type.
2) All gas fuel block and vent valve positions monitored by the control system and if any valve tracks off its assigned position an alarm is annunciated and GT purge credit cancelled.
3) Pressure monitoring of cavity at the double block and vent pipe section exceeds 10 PSIG for 5 seconds, alarm and GT purge credit is cancelled. 4) Valve Proofing via Bottle test during startup and shutdown, which provides gas fuel block valve tightness verification.

During start up on liquid fuel for dual fuel applications, as applicable, bottle test to gas fuel train is performed prior to operating on liquid fuel. If gas fuel supply supply pressure is not available (refer to PP47) during the start up on liquid fuel or if bottle test fails or if previous bottle test has failed, transfer to gas fuel is not permissible. Start up and operation on liquid fuel is permissible regardless. 5) 8-day window allowed for GT Purge Credit. If successful startup or high speed crank is not processed during this 8-day window, GT Purge Credit is lost and annunciated from the control system
6) Triple block and Double Vent valve system. External block and vent valve bottle is typically left slightly pressurized to minimum to ensure there is no entrapped air.
7) Alternatively, the entire gas fuel pipeline from the external block and vent valve bottle can be de-pressurized to ambient pressure at each shutdown. The vent valve would be commanded open and block valve closed during the 8-day window. The amount of gas release from the pipeline due to the installed pipe length and far-field noise emitted at each shutdown should be considered.

For Information Only
PP29 Rev C

Page 3 of 4 ends

¤ COPYRIGHT, 2018, GE PACKAGED POWER, L.P.,ALL RIGHTS RESERVED. THIS DRAWING IS THE PROPRIETARY AND/OR CONFIDENTIAL PROPERTY OF GE PACKAGED POWER, L.P., AND IS LOANED IN STRICT CONFIDENCE WITH THE UNDERSTANDING THAT IT WILL NOT BE REPRODUCED NOR USED FOR ANY PURPOSE EXCEPT THAT FOR WHICH IT IS LOANED. IT SHALL BE IMMEDIATELY RETURNED ON DEMAND, AND IS SUBJECT TO ALL OTHER TERMS AND CONDITIONS OF ANY WRITTEN AGREEMENT OR PURCHASE ORDER WHICH INCORPORATES OR RELATES TO THIS DRAWING.

Liquid Fuel System
Liquid fuel system is incorporated with three stop valves, with proof of closure, in series with drain valves connected between these valves (triple block and double drain valve system). The connected drain valves relieve pressure between the stop valves when GT is off line.
1) GT Purge Credit allowed following Normal Shutdown, non-related to fuel system or ESD type.
2) Monitor and ensure no liquid fuel pressure upstream of the most upstream block valve.
3) Liquid fuel block and drain valves positions continuously monitored by the control system and if any valve tracks off its assigned position an alarm is annunciated and GT purge credit cancelled.
4) Pressure monitoring of cavity at downstream bottle exceeds 3 PSIG an alarm is annunciated and GT purge credit is cancelled.
5) 8-day window allowed for GT Purge Credit. If successful startup or high speed crank is not processed during this 8-day window, GT Purge Credit is cancelled and annunciated by the control system.

If the HRSG contains duct burners, the fuel supply to these burners should include triple block and bleed valves and comply with NFPA 85 release to prevent gas leakage into an idle (or operating) boiler duct.

With GT purge credit feature active during the 8-day window the standard purge time is 30 seconds and provides at least 1.5 air changes to the engine and exhaust diffuser system. This provides standard 5 minute to full load start feature for the TM200 and is in accordance to OEM manufacture’s recommendation and conforms to NFPA 85. 8 Minute Start Cycle
8 minute start is standard start time cycle for simple cycle applications to full load, reference PP108. For combined cycle exhaust systems GT Purge Credit must be enabled to obtain 8 minute start to full load. If GT Purge Credit not active long purge timer would be deployed by the control system, which would extend the start to full load time respectively.

If required, longer or shorter purge time requirements can be accommodated provided an adequate engineering model of the exhaust system supports the adequacy of the proposed purge time.

For Information Only
PP29 Rev C

Page 4 of 4 ends

Conclusion
To request a non-standard purge time for specific applications, the customer must submit a formal request to their GE Power Aero representative with supporting documentation (dimensioned system drawings, volume calculations). This formal documentation must also include the customer’s full acceptance of responsibility for purge time and associated incidents if the requested purge time does not meet our guidelines.

For Information Only
Exhibit C - Scope Of Work

Design, procure, construct and commission all materials, equipment and systems necessary for the installation and commercial operation of the Additional Units and ancillary equipment to include the following:
• Decommission the existing Roseville Power Plant 2 (RPP2) site consisting of:
o Salvage all applicable major equipment
o Dispose of all remaining unneeded equipment
o Removal of all existing foundations and below ground facilities as necessary to accommodate repower
o Fuel gas yard, generator step-up (GSU) transformers, warehouse and equipment speciﬁcally identiﬁed by Roseville to remain
• Design, procurement and construction of major RPP2 equipment/systems consisting of the following:
o Transportation of CDWR supplied equipment from 5120 Phillip Road, Roseville to the RPP2.
o Fuel gas and gas compression system
o Chemical storage and containment
o Instrument air system
o Fire protection system
o Demineralized water system and storage
o Cathodic protection system
o Generation yard 4160V and 480V electrical systems and equipment o Control system installation and programming
o Turbine anti-icing system (optional)
o Evaporative coolers (optional)
o Civil construction of grading, ground grid, duct banks, conduit, piping and foundations
• Testing and commissioning of all Additional Units systems for commercial operation
• Design, procurement and construction of major 60kV Switchyard equipment/systems consisting of the following:
o 60kV switchyard steel structures
o 60kV circuit breakers, relay panels and control wiring (Roseville staff) o Civil construction of grading, ground grid, duct banks, conduit, piping and foundations
• Testing and commissioning of all 60kV Switchyard equipment (Roseville staff)

In order to maintain schedule to achieve a June 1, 2026, Commercial Operation Date, with the installation of gas compression and rebuild of the 60kV switchyard, the following tactics will be employed:

• Gas Compression
o For a delay in the delivery of the gas compressors, blind ﬂanges will be installed where the compressors would otherwise go. All necessary bypasses and valves will be installed as part of the system design in order to allow for operation if the gas compressors are not in place. The gas compressors will be installed and a future outage (outside the summer peak season) will be taken to ﬁnish installation and commissioning.
o For a delay in electrical equipment required to power the gas compressors, the gas compressors will be installed and bypassed and a future outage (outside the summer peak season) will be taken to ﬁnish installation and commissioning.
• 60kV Switchyard
o As the 60kV relay protection and controls need to be relocated from the Balance of Plant control building (which must be removed to accommodate the installation of the TM2500’s) to the warehouse, this work is required even if the switchyard itself is left as is. Roseville plans to procure this equipment immediately and will be able to perform construction prior to having access to work on rebuilding the 60kV yard, keeping as many substation technician resources available as possible to expedite the rebuild.
o Roseville will develop a detailed work plan for the 60kV yard rebuild to assure the necessary time is available, to determine critical path items and to have the ability to closely track progress and adjust resource allocation as necessary to maintain the schedule. o Roseville will prioritize the work that is absolutely required to connect the generating units to the 60kV system, which mainly consists of bus work and installation of the 60kV breakers for each of the GSU’s. o 60kV disconnect switches were identiﬁed in IEC’s bid as a long lead item that could jeopardize schedule. Roseville currently owns six sets of these switches that could be repurposed if necessary. As a last resort, all disconnect switch positions could be jumpered and installed during future outage (outside the summer peak season). o As a ﬁnal resort, Roseville will use existing inventory of equipment/parts to bring the facility online, including: existing 60kV circuit breakers, wood poles, overhead bare conductor and terminations. The 60kV yard would be constructed at a future outage (outside the summer peak season).

The RPP2 Site is located at:

Roseville Power Plant #2
2155 Nichols Drive
Rocklin, CA 95765

ASSET TRANSFER AGREEMENT FOR ADDITIONAL UNITS BETWEEN THE CITY

OF ROSEVILLE AND THE CALIFORNIA DEPARTMENT OF WATER RESOURCES THIS AGREEMENT (ATA) is made and entered into this ___ day of ________________, 2029, by and between the City of Roseville, a municipal corporation (“Roseville” or “Owner”), and the California Department of Water Resources (“CDWR”). Referred to as “Party” or “Parties.”

RECITALS

WHEREAS, on July 30, 2021, the Governor of the State of California proclaimed a state of emergency due to the accelerating and compounding effects of continuing wildfires, ongoing drought, and extreme heat conditions caused by climate change, which have resulted in an additional projected energy supply shortage of up to 3,500 megawatts during the afternoon- evening “net -peak” period of high power demand on days when there are extreme weather conditions. The proclamation directed CDWR to enter into contract s for the procurement of materials, goods and services necessary for projects likely to be online by October 31, 2021, that would expand energy supply and storage to respond to these projected energy supply shortages;

WHEREAS, pursuant to the emergency proclamation, Roseville and CDWR entered into three agreements , including the Site Use and Installation Agreement (Site Agreement , as amended), under the State Power Augmentation Program (“Program”) to site, install, and interconnect, and then subsequently operate and maintain, two General Electric TM2500 combustion turbine generators with selective catalytic reduction systems and their associated equipment (the “RPEAK Units”) initially through the end of 2023;

WHEREAS, the Site Agreement was subsequently amended with its Term extended to facilitate Owner’s application to and acceptance into the California Energy Commission’s Distributed Electricity Backup Assets program for the benefit of the California electric grid during grid emergencies;

WHEREAS, the Site Agreement was amended a second time to facilitate transfer of title to the RPEAK Units to Owner, and allow Owner and DWR to continue their partnership on the Program by adding additional DWR -owned generators and their associated equipment (“Additional Units”) to the Site Agreement; and

WHEREAS, the Site Agreement was amended a third time to install and operate the Additional Units through the end of the extended Term provided in the Third Amended Site Agreement; and

WHEREAS, DWR is transferring title to the Additional Units, as fully defined and inventoried in Exhibit 1 to, to Roseville in accordance with the terms and conditions of this Asset Transfer Agreement and the Site Agreement, as amended.

NOW, THEREFORE, in consideration of the mutual promises set forth herein, the Parties agree as follows:

1. Transfer. Effective November 1, 2029, CDWR hereby transfers to Roseville title to the Additional Units in exchange for the consideration identified in Section 2 below. Roseville

Page 2 of 6 ends

agrees to accept the Additional Units, subject to the terms and conditions of this ATA and the Site Agreement, which is incorporated by reference herein. The Additional Units shall be sold and accepted “AS IS” with no warranties, express or implied, of any kind whatsoever, including any warranties as may be implied at law. This transfer shall include all tangible assets associated with the Additional Units as well as CDWR’s complete interest in any intellectual property associated with the Additional Units, including the selective catalytic -reduction systems. Such transfer renders the intellectual property license granted to Roseville on November 1, 2024 for the related RPEAK Units in the prior phase of the Program moot.

2. Consideration. The Parties agree that the consideration for this ATA shall be as specified in the Site Agreement (hereinafter “Consideration”).

3. Documenting Transfer of Ownership . Any reporting or documentation of ownership transfer for regulatory or taxation purposes shall be as specified in the Site Agreement , specifically the Second Amendment.

4. Delivery and Transfer of Additional Units. The delivery and transfer of the Additional Units shall occur at midnight on November 1, 2029 at the Site in unincorporated Placer County located at 2155 Nichols Drive, Rocklin, California.. The Additional Units are located on land owned by Roseville and have been operated and maintained by Roseville.

Therefore, t here are no physical items for CDWR to provide to Roseville other than documentation associated with the transfer listed in Exhibit 2. The complete list of tangible assets is provided in Exhibit 1. CDWR will provide documentation by electronic file transfer or other means acceptable to both Parties as provided in Exhibit 2 that pertains or relates to the Additional Units. The Additional Units shall be transferred free of any liens or encumbrances.

5. Title/Risk of Loss. Title, ownership, and risk of loss or damage for the Additional Units shall transfer from CDWR to Roseville at midnight on November 1, 2029. After physical transfer of the Additional Units, Roseville shall be solely responsible for all maintenance and operation of the Additional Units, including but not limited to maintenance costs, insurance, and all items specified in the Site Agreement.

6. No Warranties or Right of Return. Roseville agrees that CDWR does not warrant the Additional Units in any way, express or implied. Roseville also agrees that it has no right to return the Additional Units. Any dispute as to the Additional Units condition or similar will first be resolved using the dispute resolution provision in the Site Agreement.

7. Indemnity. Shall be as provided in the Site Agreement, as amended.

8. Compliance with Laws . The parties acknowledges that the Additional Units may be subject to certain state and federal laws and regulations and agree to strict compliance with all applicable laws and regulations.

9. Venue; Governing Law. Any legal action arising out of this ATA shall be brought in Sacramento County, California, regardless of w here else venue may lie. This ATA shall be governed by and construed in accordance with the laws of the State of California.

Page 3 of 6 ends

10. Modification. This ATA and each provision contained herein may be waived, amended, supplemented or eliminated only by mutual written agreement of the Parties.

11. Severability. If any of the provisions contained in this ATA are for any reason held invalid or unenforceable, such holding shall not affect the remaining provisions or the validity and enforceability of the ATA as a whole.

12. Entire Agreement. This ATA, including the incorporated Site Agreement, as amended, contains the entire agreement between Roseville and CDWR in connection with the transaction contemplated hereby and the subject matter hereof and this ATA supersedes and replaces any and all prior and contemporaneous agreements, understandings, and communications between the parties, whether oral or written, with regard to the subject matter hereof or any course of dealing, course of performance, or usage of the trade. The Parties acknowledge that they have not relied on any promise, representation or warranty, express or implied, not contained in this ATA. Should any term in this ATA be deemed to be unenforceable, that term shall be removed without impact to all remaining terms. [Signature page follows]

Page 4 of 6 ends

IN WITNESS WHEREOF, the City of Roseville, a municipal corporation, has executed this agreement in duplicate and the California Department of Water Resources has caused this agreement to be duly executed.

CITY OF ROSEVILLE, a CALIFORNIA DEPARTMENT OF
municipal corporation WATER RESOURCES

BY: BY:

DOMINICK CASEY DELPHINE HOU
City Manager Deputy Director, Statewide
Energy Office

ATTEST:

By:

CARMEN AVALOS
City Clerk

APPROVED AS TO FORM: APPROVED AS TO FORM AND
LEGAL SUFFICIENCY:

BY: BY:

MICHELLE SHEIDENBERGER COLIN A. WOOD
City Attorney Attorney IV

APPROVED AS TO
SUBSTANCE: BY:

DAN BEANS
Electric Utility Director

Page 5 of 6 ends

Exhibit 1

[Additional Units Equipment List.xlsx, provided by CDWR to Roseville electronically]

Page 6 of 6 ends

Exhibit 2

[Documentation provided by CDWR to Roseville via electronic file transfer] Exhibit G- Additional Units Dispatch Protocol

1. Overview
During the Term of the Third Amended and Restated Site Use and Installation Agreement between the California Department of Water Resources (CDWR) and the City of Roseville (Roseville), the Additional Units at the Roseville Power Plant 2 site will be utilized only during times of stress on the California electric grid determined by a California Balancing Authority Area (BAA) or in support of Roseville’s reliability when Available Supply resources owned by and/or contracted with Roseville are projected to be at or below an agreed-upon Reliability Threshold, as deﬁned in Section 4.

2. Default Condition
In the default condition, the California and Roseville electric grids are functioning normally, and supply resources exceed the load forecast by a Reliability Threshold agreed upon between Roseville and CDWR, as discussed below. In this condition, the Additional Units are available but would be placed under an Environmental Outage, as deﬁned by CAISO and/or BANC operating procedures, to prevent dispatch even if market prices exceed the marginal cost for the Additional Units.

3. Support for the California Electric Grid
The Additional Units will be dispatched to support the California electric grid and California Balancing Authority Areas (BAAs) during abnormal conditions as determined by a California BAA. For the purposes of this dispatch protocol, California BAAs are deﬁned as:

1. California Independent System Operator (CAISO)

2. Balancing Authority of Northern California (BANC)

3. Imperial Irrigation District (IID)

4. Los Angeles Department of Water and Power (LADWP)

5. Turlock Irrigation District (TID)
As noted above, during the default condition, the Additional Units will be under an Environmental Outage to prevent dispatch for normal market operation. The Environmental Outage will be lifted by Roseville or its representative if either of the following conditions are declared by a California BAA or local transmission service provider:
a. An Energy Emergency Alert (EEA) Notice is issued by RC West or a California BAA 1 or
b. A local transmission emergency is declared by BANC or the Western Area Power Administration.

When either (or both ) of the above conditions exists, Roseville or its representative shall immediately remove the E nvironmental Outage card for the Additional Units and release them to be available for dispatch in the Western Energy Imbalance Ma rket (WEIM). If the Environmental Outage card is not lifted within one hour of Condition 3a occurring, a penalty of $60,000 will be assessed against Roseville for each incident. Coincident or overlapping BAA EEA events will be considered a single incident. Failure of WEIM to dispatch, failure to

1 An EEA Notice may be issued earlier than the EEA Declaration time. start, or forced outages will be deemed as excused incid ents for purposes of scheduling penalties for the Additional Units.

4. Roseville Reliability Support
In addition to Conditions 3a and 3 b, the Additional Units may be utilized for the following conditions to support Roseville’s reliability during stressed system conditions:
a. Reliability Threshold - Roseville’s Scheduling Coordinator declares that the total of Roseville ’s Available Supply including owned and contracted resources, cannot meet at least 108% of Roseville’s forecasted load in the Real-Time Market (i.e., the Western Energy Imbalance Market). i. Available Supply – Available Supply is the total supply owned and contracted for by Roseville less the Additional Units, and reduced by various real -time conditions such as planned, unplanned or forced outages, derating of the transmission system used by Roseville for energy delivery, and hydro derates due to drought. Planned outages for the Additional Units will only take place between November 1st and April 30th.

b. Maintenance and testing of the Additional Units.

During Conditions 4a and 4b described above, Roseville or its representative may lift the Environmental Outage card or base schedule the Additional Units for the duration of the event. The Additional Units will be shut down and return to the default condition within one hour after Available Supply resources exceed load by the agreed-upon Reliability Threshold.

5. Reporting
By December 15 of each year, Roseville shall provide a report to CDWR capturing the prior 12 months (November 1 – October 31). The report shall document the periods when Roseville had utilized the Additional Units under Conditions 4a and 4b. For Condition 4a, Roseville shall provide a summary at hourly granularity of when Available Supply was at or below the Reliability Threshold. For Condition 4b, Roseville shall provide a summary at daily granularity when the Additional Units were online for maintenance and testing and a brief description of the maintenance work and testing rationale. The annual report shall utilize settlement quality meter data, to conform to standards consistent with reporting to State and Federal regulatory bodies, and be signed by Roseville Electric’s Utility Director or Chief Operating Officer as true and correct to the best of their knowledge.

By March 1 or the next business day of each year, Roseville shall provide CDWR with copies of any Quarterly Emissions Report(s) submitted to the United States Environmental Protection Agency (EPA), and by April 15 or the next business day of each year, shall provide copies of the Greenhouse Gas (GHG) emissions report (s) submitted to the California Air Resources Board (CARB) for the emissions of the Additional Units for the prior calendar year (January 1 – December 31), and any other emissions data requests for the Additional Units on which CDWR and Roseville mutually agree.

Roseville will develop a procedure, with input from CDWR, for prompt EEA event noticing to CDWR, and distribution of raw meter data from the Additional Units by the following morning.

6. Amendment
This Additional Units Dispatch Protocol may be amended in writing only by mutual agreement of the Parties , including temporary adjustment to the Reliability Threshold for exigent circumstances.

1 THIS SECOND AMENDED AND RESTATED OPERATIONS AND MAINTENANCE AGREEMENT (“Agreement”), dated as of the date of the last signature below (the “Effective Date”), is made by and between the CALIFORNIA DEPARTMENT OF WATER RESOURCES (“CDWR” or “Owner”) and the CITY OF ROSEVILLE, a municipal corporation (“ROSEVILLE” or “O&M Contractor”). Each of Owner and O&M Contractor are also referred to herein as a “Party” and collectively as the “Parties”.

RECITALS

A. On July 30, 2021, the Governor of the State of California proclaimed a state of emergency due to the accelerating and compounding effects of continuing wildfires, ongoing drought, and extreme heat conditions caused by climate change, which h ave resulted in an additional projected energy supply shortage of up to 3,500 megawatts during the afternoon - evening “net -peak” period of high power demand on days when there are extreme weather conditions. The proclamation directs CDWR to enter into cont racts for the procurement of materials, goods and services necessary for projects likely to be online by October 31, 2021, that would expand energy supply and storage to respond to these projected energy supply shortages.

B. Pursuant to the foregoing proclamation, CDWR has purchased and currently owns two General Electric TM2500 combustion turbine generators with selective catalytic reduction systems (the “Additional Units”) and has entered into the Site Agreement (as defined below) to obtain a site on whi ch the Facility can be installed and operated through October 31, 2029 , at which time the Additional Units would be purchased by Roseville . The Facility will be used to provide additional energy supplies to the California electric grid during grid emergencies as well as Roseville’s local reliability needs during stressed conditions during this period.

C. CDWR wishes to engage Roseville to act as O&M Contractor of, and provide maintenance services for the Additional Units, and Roseville is willing to provide such services on the terms and conditions set forth herein.

NOW, THEREFORE, for good and valuable consideration, the Parties agree as follows:

1. Definitions; Rules of Interpretation.

Definitions. Unless otherwise required by the context in which a defined term appears, the following terms shall have the meanings specified in this Section 1. Terms that are defined in other Sections shall have the meanings given to them in those Sections.

“Additional Units” shall have the same meaning as provided in the concurrently executed Third Amended Site Use and Installation Agreement.

“BANC” means the Balancing Authority of Northern California, the Balancing Authority in which Roseville is located.

"Bankrupt" means with respect to any entity, such entity (i) files a petition or otherwise commences, authorizes or acquiesces in the commencement of a proceeding or cause of action under any bankruptcy, insolvency, reorganization or similar law, or has any such petition filed or commenced against it and such petition filed or commenced against it is not stayed or dismissed within ninety (90) days thereafter, (ii) makes an assignment or any general arrangement for the benefit of creditors, (iii) otherwise becomes bankrupt or insolvent (however evidenced), (iv) has a liquidator, administrator, receiver, trustee, conservator or similar official appointed with respect to Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

2 it or any substantial portion of its property or assets, or (v) is generally unable to pay its debts as they become due.

“Business Day” means any day other than Saturday, Sunday, and any day that is a holiday observed by Federal Reserve member banks in San Francisco, California.

“CAISO” means the California Independent System Operator Corporation or any successor entity performing similar functions.

"Confidential Information” means any information disclosed in writing or orally by one Party to the other Party that is or relates to (a) the terms and conditions of, and proposals and negotiations related to, this Agreement, (b) information (i) necessary to protect the reliability and security of each Party’s electric systems, (ii) defined as Critical Energy Infrastructure Information, as defined in Title 18 of the Code of Federal Regulatio ns, or (iii) related to any aspect of the business of a Party which is either information not known by actual or potential competitors of the other Party or is proprietary information of a Party, whether of a technical nature or otherwise and is marked as such, or (c) information that the Disclosing Party stamps or otherwise identifies as “confidential” or “proprietary” before disclosing it to the Receiving Party; provided however, that Confidential Information shall not include (i) information that was publicly available at the time of the disclosure, other than as a result of a disclosure in breach of this Agreement; (ii) information that becomes publicly available through no fault of the Receiving Party after the time of the delivery; (iii) information th at was rightfully in the possession of the Receiving Party (without confidential or proprietary restriction) at the time of delivery or that becomes available to the Receiving Party from a source not subject to any restriction against disclosing such infor mation to the Receiving Party; and (iv) information that the Receiving Party independently developed without a violation of this Agreement.

"Contract Year" has the same meaning as in the Site Agreement.

“Environmental Law” means any Law or Permit, or any lawfully promulgated regulation implementing such Law, and any binding judicial or administrative interpretation or requirement thereof, pertaining to (i) the regulation or protection of employee health or safety, public health or safety, or the ind oor or outdoor environment; (ii) the conservation, management, development, control or use of land, natural resources, or wildlife; (iii) the protection or use of surface water or ground water; (iv) the management, manufacture, possession, presence, use, g eneration, treatment, storage, disposal, transportation, or handling of, or exposure to any Hazardous Substances; or (v) pollution (including release of any hazardous substance to air, land, surface water and ground water), including the Comprehensive Environmental Response, Compensation and Liability Act, the Superfund Amendments and Reauthorization Act of 1986, the Hazardous Material Transportation Act, the Resource Conservation and Recovery Act of 1976, the Toxic Substances Control Act, the Federal Water Pollution Control Act, the Clean Water Act, the Clean Air Act, the Occupational Safety and Health Act, any so -called “superlien” law, all as now or hereafter amended or supplemented, and any regulations promulgated thereunder, and any other similar federal, state, or local statutes, rules and regulations.

“EPC Contractor” has the same meaning as in the Site Agreement.

“Good Industry Practice ” means those practices, methods and acts that would be implemented and followed by prudent builders, owners, lesso rs, and operators of electric generation facilities similar to the Units in the western United States during the relevant time period, which practices, methods and acts, in the exercise of prudent and responsible professional Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

3 judgment in the light of the facts known at the time the decision was made, could reasonably have been expected to accomplish the desired result consistent with good business practices, reliability and safety, and shall include, at a minimum, those professionally responsible practices, methods and acts described in the preceding sentence that comply with manufacturers’ warranties, restrictions in this Agreement, and the requirements of governmental authorities, NERC or WECC reliability standards, the CAISO and Applicable Laws. Good Industry Practice is not intended to be the optimum practice, method or act to the exclusion of all others, but rather is intended to be any of the practices, methods and/or actions generally accepted in the region.

“Governmental Authority” means any federal, state, local or municipal government, any political subdivision thereof or any other governmental, regulatory or judicial instrumentality, authority, body, agency, department, bureau, or entity with authority to bind a Party at law, including CAISO; provided, however, that “Governmental Authority” shall not in any event include any Party.

“Hazardous Substances” means (a) any chemical, material or substance that is listed or regulated under applicable Laws as a “hazardous” or “toxic” substance or w aste, or as a “contaminant” or “pollutant” or words of similar import, (b) any petroleum or petroleum products, flammable materials, explosives, radioactive materials, asbestos, urea formaldehyde foam insulation, and transformers or other equipment that co ntain polychlorinated biphenyls, and (c) any other chemical or other material or substance, exposure to which is prohibited, limited or regulated by any Laws.

“Law” means any law, statute, rule, regulation, decision, writ, order, decree or judgment, permit, license or authorization, or any lawfully promulgated regulation or any interpretation thereof, promulgated, adopted or issued by a Governmental Authority.

“Major Equipment Failure” has the meaning defined in the Site Agreement.

“NERC” means the North American Electric Reliability Corporation or any successor thereto.

“NERC Reliability Standards” shall mean the mandatory reliability standards developed by NERC and approved by the Federal Energy Regulatory Commission , as they apply to the Additional Units.

"Operations and Maintenance Manuals" means the operating data, design drawings, specifications, vendors' manuals, warranty requirements, procedures (including those for maintenance of the Additional Units and environmental and safety compliance), a nd similar materials with respect to the Additional Units.

“Permit” means any permit, authorization, consent, approval, license, order, filing, waiver, exception, variance or exemption filed with or issued by any Governmental Authority and shall include t hose siting and operating permits and licenses required for the installation, testing, commissioning, operation, maintenance, decommissioning or removal of the Units in compliance with all applicable Laws.

"Process Documentation" has the meaning set forth in Section 6.1.

"Project" means the installation, testing, commissioning, and operating the Additional Units at the Site.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

4 "Project Agreements" means the agreements between CDWR and Roseville relating to the Project, including a ny Interconnection Agreement, this Agreement , Maintenance Service Agreement and Warranty Agreement and all other agreements applicable to the Project, permits, and licenses required for the operation, maintenance and management of the Project, as identified in writing by Owner.

"Reimbursable Costs" has the meaning set forth in Section 5.3.

"Services" has the meaning set forth in Section 3.1.

“Site” means the area designated as the “Site” on Exhibit A of the Third Amended and Restated Site Use and Installation Agreement.

“Site Agreement ” means that certain Third Amended and Restated Site Use and Installation Agreement, as amended, dated as of the Effective Date of that agreement, by and between Roseville, as licensor, and CDWR, as licensee.

“WAPA” has the same meaning as in the Site Agreement.

“WECC” means Western Electricity Coordinating Council or any successor thereto.

“WEIM” has the same meaning as in the Site Agreement.

1.2 Rules of Interpretation.

(a) The following rules of interpretation shall apply to this Agreement, unless otherwise specified or required by the context:

(i) Terms defined in the singular shall include the plural and vice versa;

(ii) References to “Sections” and “Exhibits” shall be to sections or exhibits of this Agreement;

(iii) All references to a particular entity shall include a reference to such entity’s successors and permitted assigns;

(iv) The words “herein,” “hereof,” and “hereunder” shall refer to this Agreement as a whole and not to any particular section or subsection hereof;

(v) References to this Agreement shall include a reference to all exhibits hereto, as the same may be amended, modified, supplemented, or replaced from time to time;

(vi) Terms used in the masculine shall include the feminine and vice versa;

(vii) The terms “include” and “including,” when used in this Agreement, shall mean to include without limitation; and

(viii) The term “day” when used in this Agreement shall mean a calendar day unless specified otherwise.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

5 (b) Capitalized terms, used but not otherwise defined herein, shall have the meaning ascribed to them in the CAISO Tariff.

(c) Any and all logs, records, reports, and other documents required to be maintained or provided to CDWR by Roseville may be provided in electronic form.

2. Engagement of O&M Contractor.

2.1. Engagement. Owner hereby engages O&M Contractor as an independent contractor to operate, and maintain and repair, to the extent required herein, the Additional Units on the Site, to perform certain administration and management services, and to perform certain other duties, all as set forth in this Agreement. O&M Contractor accepts such engagement and agrees to perform in accordance with the terms and conditions hereof.

2.2. Relationship. O&M Contractor is an independent contractor of Owner with respect to the performance of its obligations hereunder. Neither O&M Contractor nor its Affiliates, employees, subcontractors, vendors or suppliers, or the employees of any such parties employed in connection with this Agreement shall be deemed to be agents, representatives, employees, or servants of Owner. O&M Contractor shall not have the right or authority to assume, create or incur any liability or obligation, express or implied, against, in the name of, or on behalf of Owner. This Agreement is not intended to create, and shall not be construed to create, a relationship of partnership or an association of profit between Owner and O&M Contractor.

2.3. Engagement of Third Parties.

O&M Contractor may engage third party subcontractors for the purpose of performing Scheduled Maintenance, Emergency Actions, or other actions pursuant to Sections 3.8 and 3.9 under this Agreement; provided, however, that such engagement shall not relieve O&M Contractor of any of its obligations or liabilities under this Agreement, including those set forth in Section 14; and provided further that O&M Contractor’s use of Subcontractors shall not modify or increase the compensation payable to O&M Contractor pursuant to Section 5.

As between Owner and O&M Contractor, and subject to the limitation of liability set forth in Section 14.2 herein, O&M Contractor shall be solely responsible for the acts, errors, omissions and defaults of its subcontractors and their employees, and all Persons engaged by O&M Contractor pursuant to this Section 2.3 with respect to services provided by such Person on behalf of O&M Contractor. Nothing in this Agreement shall be construed to impose on Owner any obligation, liability or duty to a subcontractor, or to create any contractual relationship between such subcontractor and Owner, including the obligation to pay or see to the payment of any moneys due such Subcontractor.

SECTION 3. SERVICES TO BE PROVIDED; DUTIES OF O&M CONTRACTOR.

3.1. Scope of Services. In consideration of the CDWR EPC Payment (as defined in Section

5.1) payable to O&M Contractor hereunder, O&M Contractor agrees to operate and maintain, to the extent required herein, the Additional Units at the Site in accordance with the terms of this Agreement and in accordance with the standards set forth herein, and in furtherance thereof to provide the following services during the Term of this Agreement.

O&M Contractor shall (i) operate, maintain and manage , to the extent required herein, the Additional Units on behalf of Owner (“Services”) and (ii) also perform the specific duties set forth Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

6 in this Agreement if they are not otherwise required by the standards defined in Section 3.2 and Exhibit A.

3.2. Standards for Performance of the Services. O&M Contractor shall perform the Services required under this Agreement, including those set forth in Exhibit A, in a prudent, reasonable, and efficient manner and in accordance with (i) Operating Manuals, the Process Documentation (as defined in section 6.1) and applicable vendor warranties, (ii) [RESERVED], (iii) all applicable Laws, (iv) Good Industry Practice, (v) the Project Agreements, (vi) the requirements of BANC and WAPA instructions, tariffs, and business practices , and (vii) all insurance policies specified in Section 12 of this Agreement. O&M Contractor shall use all reasonable efforts to optimize the useful life of the Additional Units and to minimize Project outages or other unavailability.

3.3 General Operating Standards.

(a) In performing its obligations hereunder, O&M Contractor shall use commercially reasonable efforts to be consistent with the requirements of this Agreement and the Project Agreements, and shall use commercially reasonable efforts in meeting the Parties’ respective goals for the Additional Units, this Agreement, the Site Agreement, and the dispatch protocol attached to the Site Agreement.

(b) O&M Contractor shall take all necessary steps to cause the Additional Units to operate in accordance with all applicable Laws or other requirements, including those set forth by the North American Electric Reliability Corporation, Environmental Laws, and safety laws, in each case, to the extent applicable to O&M Contractor’s scope of work hereunder.

(c) O&M Contractor shall perform its obligations hereunder in accordance with the terms of this Agreement, Good Industry Practice, applicable Laws (including Environmental Laws and Safety Laws), and Permits,.

(d) [RESERVED]

3.4. O&M Contractor’s Personnel Standards. O&M Contractor shall provide as reasonably necessary all labor and professional, supervisory and managerial personnel as are required to perform the Services. Such personnel shall be qualified to perform the duties to which they are assigned and shall meet any requirements for Project personnel under the Project Agreements.

Working hours, rates of compensation and all other matters relating to their employment of all individuals employed by O&M Contractor to perform the Services shall be determined solely by O&M Contractor (other than any indirect impact on matters relating to employment that may result from the Owner's approval rights with respect to the Annual Budget). With respect to labor matters, hiring personnel, and employment policies, O&M Contractor shall comply with all applicable Laws. O&M Contractor also shall act in a reasonable manner that is consistent with the intent and purpose of this Agreement and with O&M Contractor’s acknowledgment (hereby given) that O&M Contractor has no authority to enter into any contracts with respect to labor matters that purport to bind or otherwise obligate Owner.

3.5. Operating Records and Reports. O&M Contractor shall maintain, in electronic form accessible to Owner, the Project operating logs, records, and reports that document the operation and maintenance of the Project, all in form and substance sufficient to meet Owner's reporting requirements under the Project Agreements. O&M Contractor shall maintain current revisions of drawings, specifications, lists, clarifications and other materials related to operation and maintenance of the Project provided to O&M Contractor by Owner and vendors. O&M Contractor Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

7 shall provide Owner reasonably necessary assistance in con nection with Owner's compliance with reporting requirements under the Project Agreements, applicable Laws or any other agreement to which Owner is a party relating to the Project. Such assistance shall include providing in electronic form reports, records , logs and other information that Owner may reasonably request as to the Project or its operation.

3.6. No Liens or Encumbrances. O&M Contractor shall maintain the Project free and clear of all liens and encumbrances resulting from any action of O&M Contractor or work done at the request of O&M Contractor , except for such liens or encumbrances that result directly from nonpayment by Owner of amounts due and owing to O&M Contractor under this Agreement.

3.7. No Action. Except where such action is e xpressly permitted by this Agreement, O&M Contractor shall not take any action that would cause a default under any Project Agreement.

3.8. Emergency Action. If an emergency endangering the safety or protection of persons, the Additional Units , or property located near the Additional Units occurs, O&M Contractor shall promptly notify Owner and take all necessary action to attempt to prevent or mitigate any such threatened damage, injury or loss. O&M Contractor shall make reasonable efforts to minimize any cost associated with remedial action in case of such an emergency.

3.9. Overhaul of Major Equipment and Capital Improvements. The cost of all major equipment teardowns and overhauls and all capital improvements shall be the responsibility of Roseville. Roseville agrees to insure the Additional Units against all Major Equipment Failures.

SECTION 4. OWNER RESPONSIBILITIES

4.1. Information. Owner shall provide O&M Contractor with all vendor manuals, spare parts lists, Project data books and drawings which are provided to Owner pursuant to any Project Agreement or by any contractor responsible for construction, installation, repair or maintenance of the Project or a part thereof. Subject to the standards of performance set forth in Section 3.2, O&M Contractor shall be entitled to rely upon such information in performance of the Services.

Owner shall also provide O&M Contractor with copies of all Pr oject Agreements and any amendments thereto and any other documents that define the Additional Units’ operating requirements.

4.2. [RESERVED

4.3. [RESERVED]

Section 5. Compensation.

5.1. Payments. As compensation to O&M Contractor for performance of the Services hereunder, CDWR will pay to Roseville the sum of eight million dollars ($8,000,000) toward Owner’s EPC Contractor costs of installation, testing, and commissioning the Additional Units (“CDWR EPC Payment”). The CDWR EPC Pa yment will be billed based on the milestone payment schedule provided by Roseville’s EPC Contractor. The first four million dollars ( $4,000,000) will be paid based on invoice from Roseville after approval of Roseville’s contract with its EPC Contractor by the Roseville City Council. The second four million dollars ( $4,000,000) will be paid based on invoice from Roseville upon commencement of decommissioning of the existing Roseville-owned generators at the Site as provided in Exhibit C. The eight million dollars ($8,000,000) may be paid from either this Second Amended Operations and Maintenance Agreement or the Third Amended and Restated Site Use and Installation Agreement , or both. But in no event shall the CDWR EPC Payment exceed $8,000,000 across these two agreements.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

8 5.2. [RESERVED]

5.3. [RESERVED]

5.4. [RESERVED]

5.5. Billing and Payment.

Roseville shall invoice CDWR for the CDWR EPC Payments provided in Section 5.1. Within 45 days after receipt of any such invoice, CDWR shall:

(a) The CDWR EPC Payment shall be payable by CDWR to Owner in accordance with the amounts and dates set forth in Section 5.1 on or before the forty-fifth (45th) day after receipt of the invoice (California Prompt Payment Act; Government Code, Section 927, et seq) . If the due date falls on a non-Business Day, then the payment shall be due on the following Business Day. Payment shall be deemed delivered on time if sent via electronic funds transfer, as set forth in Exhibit E, prior to 5 p.m. Pacific time on the due date. CDWR shall submit all payments under this Agreement to Owner at the payment address shown in Exhibit C. Any changes to the address designated for purposes of payment must be made by written notice to CDWR at the address listed in Exhibit C at least sixty (60) days prior to the first submittal of payment to the new address.

(b) The CDWR EPC Payment is a fixed amount and is not subject to dispute. If it is determined by a court of applicable jurisdiction that a disputed amount or part thereof that was paid was not in fact due and owing, Owner shall refund such amount to CDWR within thirty (30) days after resolution of such dispute, together with interest on such amount from the date paid to, but not including, the date refunded at the interest rate set forth in the California Prompt Payment Act (Government Code Section 927 et seq.).

(c) Penalties for delinquent payments shall be assessed in accordance with the California Prompt Payment Act (Government Code Section 927 et seq.) as may be amended. Interest on delinquent amounts (including amounts determined to be owed as a result of the resolution of a billing dispute) shall be calculated at the interest rate specified in the California Prompt Payment Act (Government Code Section 927 et seq.) as may be amended: from the original due date (or, for amounts not properly invoiced, the date that would have bee n the due date if such amounts were properly invoiced) to the date of payment.

Section 6. PROCEDURES, PLANS AND REPORTING

6.1. Process Documentation. Upon the execution of this Agreement, the parties will develop documented processes for any necessary (i) reporting and correspondence pursuant to this Agreement, (ii) procurement and contracting, and (iii) accounting, bookkeeping and record - keeping. The Process Documentation will outline the covered activities of O&M Contractor for the term of this Agreement, subject to such revision and amendment as agreed in writing by Owner and O&M Contractor.

6.2. [RESERVED]

6.3. [RESERVED]

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

9 6.4. Accounts and Reports. Any accounting and reporting for the Additional Units shall be as provided in the Site Agreement.

Section 7. Term. This Agreement will be effective as of the Effective Date and will continue in effect until October 31, 2029, unless sooner terminated as provided herein (the “ Term”). There are no rights to extend the Term beyond that date.

Section 8. Force Majeure.

8.1 Definition. “Force Majeure” means: any cause or event beyond the reasonable control of the affected Party which causes the affected Party to fail to perform that (i) was not specifically foreseeable as of the Effective Date; (ii) was not due to the fault or negligence of the affected Party, and (iii) could not reasonably have been avoided, overcome, prevented, or mitigated, by the affected Party’s exercise of due diligence and use of reasonable precautions and efforts. Subject to the foregoing requirements, events that could qualify as Force Majeure include (a) acts of God, such as droughts, floods, earthquakes, volcanic eruption, epidemics, pandemics or other natural disasters, (b) fires, explosions, or accidents that could not have been prevented by acting in accordance with Good Industry Practice, or ( c) war (declared or undeclared), riots, insurrection, rebellion, acts of the public enemy, acts of vandalism, terrorism and/or sabotage, civil disturbance, publ ic disorder, blockades, embargoes, sanctions, import - export controls, or industry-wide strikes. However, Force Majeure shall not include the following events except the portions of such events caused solely by an event of Force Majeure as enumerated in clauses (a), (b) and (c) of the preceding sentence: (1) general market conditions or the economic hardship of either Party, (2) events arising from the failure to operate or maintain the Units in accordance with Good Industry Practice, (3) events that merely increase the cost of a Party’s performance; (4) failure of third parties to provide goods or services essential to a Party’s performance, (5) mechanical breakdown, or electrical breakdown, or failure of any machinery or equipment constituting all or part of the Additional Units, (6) [Reserved], (7) [Reserved], (8) any delay in obtaining, or denial of, any Permit, (9) any delay in providing, failure to obtain, or cancellation of, interconnection service, (10) the inability of a Party to make payments when due under this Agreement, (1 1) a strike, work stoppage or labor dispute limited only to a Party, its contractors, and their respective Affiliates or subcontractors or any other third party employed by such Party to perform its obligations hereunder, or (12) any delay resulting from litigation relating to or affecting the Additional Units or the Site.

8.2 Effect of Force Majeure. To the extent either Party is prevented by Force Majeure from carrying out, in whole or part, its obligations under this Agreement, and such Party (the “Claiming Party”) gives notice and details of the Force Majeure to the other Party as soon as practicable, then, unless as otherwise expressly provided herein , the Claiming Party shall be excused from the performance of its obligations (other than the obligation to make payments then due or becoming due with respect to performance prior to the For ce Majeure) to the extent affected by the Force Majeure, and no Event of Default shall occur as a result of the failure to perform any excused obligation. The Claiming Party shall remedy the Force Majeure with all reasonable dispatch. The non -Claiming Pa rty shall not be required to perform or resume performance of its obligations to the Claiming Party corresponding to the obligations of the Claiming Party excused by Force Majeure. If a Force Majeure event continues for six months, either party may terminate this Agreement upon proper notice under Section 10.1(a)(1).

8.3 Notice of Force Majeure. Any Party claiming Force Majeure shall advise the other Party as soon as possible of the occurrence of the Force Majeure event and shall provide the other Party with the basis of the claim, in writing, within ten (10) days of the occurrence of the Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

10 Force Majeure event. The Parties shall make reasonable efforts to avoid the adverse impacts of a Force Majeure and to resolve the event or occurrence once it has occurred to resume performance.

8.4 [RESERVED.]

Section 9. Events of Default . An “Event of Default” shall mean, with respect to a Party (a “Defaulting Party”), the occurrence of any of the following:

(a) With respect to either Party:

(i) the failure to make, when due, any payment required pursuant to this Agreement if such failure is not reme died within fifteen (15) Business Days after written notice of the failure,

(ii) any representation or warranty made by such Party herein is false or misleading in any material respect when made or when deemed made or repeated if the representation or warranty is continuing in nature, which misrepresentation or breach of warranty is not cured within thirty (30) days after written notice thereof,

(iii) except for an obligation to make payment when due, the failure to perform any material covenant or oblig ation set forth in this Agreement (except to the extent constituting a separate Event of Default or to the extent excused by a Force Majeure) if such failure is not remedied within sixty (60) days after written notice (or a reasonable amount of time in the case of a Major Equipment Failure), which written notice sets forth in reasonable detail the nature of the failure; provided, however, that if such failure is not reasonably capable of being remedied within the sixty (60) day cure period, such Party shall have such additional time (not exceeding an additional ninety (90) days) as is reasonably necessary to remedy such failure, so long as such Party promptly commences and diligently pursues such remedy;

(iv) Such Party becomes Bankrupt;

(v) Such Party co nsolidates or amalgamates with, or merges with or into, or transfers all or substantially all of its assets to, another entity and, at the time of such consolidation, amalgamation, merger or transfer, the resulting surviving or transferee entity fails to assume all the obligations of that Party under this Agreement to which it or its predecessor was a party by operation of law or pursuant to an agreement reasonably satisfactory to the other Party;

(vi) Such Party assigns this Agreement or any of its rights hereunder other than in compliance with Section 15;

(vii) A default under the provisions of the Site Agreement; or

(viii) A Force Majeure event continues for six (6) months, as described in Section 8.2.

10. Remedies; Termination Rights.

10.1 Remedies for Events of Default.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

11 (a) If an Event of Default with respect to a Defaulting Party has occurred and is continuing, the other Party (“ Non-Defaulting Party”) shall have the right to do any one of more of the following, which rights shall be cumulative and in addition to the rights of the Parties otherwise provided in this Agreement:

(i) Terminate this Agreement by sending a written notice, designating a d ay, no earlier than the day such notice is deemed to be received and no later than sixty (60) days after such notice is deemed to be received, as an early termination date of this Agreement (“Early Termination Date”);

(ii) Accelerate all amounts owing bet ween the Parties as of the Early Termination Date;

(iii) Withhold any payments due to the Defaulting Party under this Agreement pending resolution of amounts owed by or to each Party;

(iv) Suspend performance of its obligations under this Agreement;

(v) Subject to Section 14, recover monetary damages as allowed by law; and

(vi) Exercise any other rights or remedies available at law or in equity to the extent otherwise permitted under this Agreement;

(b) The Non-Defaulting Party’s election to exercise o r not exercise any of the above rights following an Event of Default shall not constitute a waiver by the Non -Defaulting Party of any remedy with respect to any subsequent Event of Default by the Defaulting Party. Amounts accelerated pursuant to Section 10.1(a)(ii) shall be netted, and the Party owing the net amount shall pay such amount to the other Party (or apply such amount against other amounts owed by the Defaulting Party, if the Non-Defaulting Party owes the net amount).

10.2 [RESERVED].

10.3 Other Termination Rights. In addition to a Non -Defaulting Party’s right to terminate as the result of an Event of Default with respect to the Defaulting Party, ROSEVILLE will have the following rights to terminate this Agreement by sending written notice designating an Early Termination Date in the same manner as provided in Section 10.1(a)(i) (although such termination is not due to an Event of Default). Any such termination shall be with no further liability on the part of either Party, except all indemnification obligations in Section 11 shall survive such termination and shall continue in effect. ROSEVILLE may terminate this Agreement if:

(a) [Reserved];

(b) ROSEVILLE reasonably determines that, through no default or failure of either Party, the Additional Units cannot be operated or dispatched in compliance with applicable Laws or Permits;

(d) the Site Agreement is terminated for any reason.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

12 10.4. [Reserved]

11. Indemnification.

11.1 Indemnification By CDWR. To the fullest extent allowed by law, CDWR shall indemnify, defend, save and hold harmless ROSEVILLE, its Affiliates and their respective officers, directors, employees, partners, lenders, agents and representatives, and their respective successors and assigns (collectively, the “ROSEVILLE Indemnified Parties”) from and against any and all losses, claims, demands, damages, liabilities, judgments, fines, penalties, costs and expenses, including reasonable attorneys’ fees, expert fees and court costs (“Losses”), incurred by or asserted against any ROSEVILLE Indemnified Party arising out of or resulting from (i) any injury or damage to persons or property as a result of any acts or omissions of CDWR, its employees, agents, representatives, contractors or subcontractors in, on or about the Additional Units or in the performance of any work or activities related to this Agreement , or (ii) the breach of any covenant or representation made by CDWR under this Agreement.

11.2 Indemnification By ROSEVILLE. To the fullest e xtent allowed by law, ROSEVILLE shall indemnify and hold harmless CDWR and its officers, directors, employees, agents and representatives, and their respective successors and assigns ( collectively, the “CDWR Indemnified Parties ”) from and against any and a ll Losses incurred by or asserted against any CDWR Indemnified Party arising out of or resulting from (i) any injury or damage to persons or property caused by the gross negligence or willful misconduct of ROSEVILLE, its employees, agents, representative, contractors or subcontractors in, on or about the Units or in the performance of any work or activities related to this Agreement, or (ii) the breach of any covenant or representation made by ROSEVILLE under this Agreement.

11.3 Indemnification Procedure. Promptly following receipt by an Indemnified Party of notice of a matter subject to indemnification under Section 11.1 or 11.2, as applicable, including the commencement of any action, administrative or legal proceeding, or investigation as to which an indemnity provided for in Section 11.1 or 11.2, as applicable, may apply the Indemnified Party shall give the Indemnifying Party written notice of such matter. The Indemnifying Party shall assume the defense of such matter with, if applicable, counsel designated by the Indemnifying Party and reasonably satisfactory to the Indemnified Party, provided, if both the Indemnified Party and the Indemnifying Party are involved in such matter (including as co -defendants) and the Indemnified Party shall have reasonably concluded that there may be legal defenses available to it which are different from or additional to, or inconsistent with, those available to the Indemnifying Party or that there is a conflict of interest between the interests of the Indemnified Party and the Indemnifying Party in such matter, the Indemnified Party shall have the right to select and be represented by separate counsel, at the Indemnifying Party’s expense. If the Indemnifying Party fails to assume the defense of a claim or other matter properly indemnifiable under Section 9.1 or

11.2, as applicable, the Indemnified Party may at the expense of the Indemnifying Party contest, settle, or pay such claim as it considers appropriate.

11.4 Survival. The provisions of this Section 11 shall survive the termination of this Agreement.

12. Insurance. Each Party will obtain and maintain in force the insurance described in Exhibit D. However, such insurance shall not be a limitation on a Party’s liabilities or obligations hereunder, nor will failure to obtain or maintain any insurance relieve a Party of any such obligations or liabilities. Each Party shall be responsible for all deductible amounts under such insurance policies. Roseville also agrees that it will maintain an insurance policy(ies) with terms Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

13 to be agreed upon by CDWR that insures against Major Equipment Failures. Such agreement by CDWR shall not be unreasonably withheld and CDWR agrees to cooperate with Roseville in insurance procurement. However, such insurance shall not be a limitation on a Party’s liabilities or obligations hereunder, nor will failure to obtain or maintain any insurance relieve a Party of any such obligations or liabilities. Each Party shall be responsible for all deductible amounts under such insurance policies. Roseville agrees that the only deductible amounts that may be claimed against the yearly Limitation of Liability provided in Section 1 4 are those attributable to claims related to the Additional U nits, including if necessary a prorated calculation of the value of the Additional Units compared to all assets insured under the policy. The Parties agree they may adjust the insurance coverage on the Additional Units during the Term, if conditions change.

13. Representations and Warranties . As of the Effective Date, each Party represents and warrants to the other Party that:

(a) it is duly organized, validly existing and in good standing under the laws of the jurisdiction of its formation;

(b) except for the Permits necessary for the installation and operation of the Units, it has received all regulatory authorizations necessary for it to legally perform its obligations under this Agreement;

(c) the execution, delivery and performance of this A greement are within its powers, have been duly authorized by all necessary action and do not violate any of the terms and conditions in its governing documents, any contracts to which it is a party or any applicable Law;

(d) this Agreement, and any other document executed and delivered in accordance with this Agreement, constitutes its legally valid and binding obligation enforceable against it in accordance with its terms, subject to Laws of general applicability limiting the enforcement of creditors’ rights and to any equitable defenses;

(e) it is not Bankrupt and there are no proceedings pending or being contemplated by it or, to its knowledge, threatened against it which would result in it being or becoming Bankrupt; and

(f) there is not pending or, t o its knowledge, threatened against it any legal proceedings that could materially adversely affect its ability to perform its obligations under this Agreement.

14. Limitations of Liability.

14.1 CDWR Liability. Amounts due under this Agreement from C DWR shall not be payable from funds available in the State Water Resources Development Fund (which is authorized by statute at sections 12930 et seq. of the California Water Code), or any successor fund to which the funds currently allocated to the State Water Resources Development Fund may be reallocated to the extent such reallocated fund represents amounts dedicated to the State Water Resources Development Fund . Notwithstanding anything herein to the contrary, except for liability resulting from its gross negligence or willful misconduct, CDWR’s liability under this Agreement shall not exceed $9,000,000 between this Agreement and the Site Agreement.

14.2 ROSEVILLE Liability. Notwithstanding anything herein to the contrary, except for liability resulting from its gross negligence or willful misconduct, ROSEVILLE’s liability under this Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

14 Agreement in any Contract Year shall not exceed $3,500,000 between this Agreement and the Site Agreement.

14.3 General Limitations. THE PARTIES CONFIRM THAT THE EXPRESS

REMEDIES AND MEASURES OF DAMAGES PROVIDED IN THIS AGREEMENT SATISFY THE ESSENTIAL PURPOSES HEREOF. FOR BREACH OF ANY PROVISION FOR WHICH AN

EXPRESS REMEDY OR MEASURE OF DAMAGES IS PROVIDED, SUCH EXPRESS REMEDY

OR MEASURE OF DAMAGES SHALL BE THE SOLE AND EXCLUSIVE REMEDY, THE

OBLIGOR'S LIABILITY SHALL BE LIMITED AS SET FORTH IN SUCH PROVISION AND ALL OTHER REMEDIES OR DAMAGES AT LAW OR IN EQUITY ARE WAIVED. EXCEPT AS

EXPRESSLY PROVIDED IN THIS AGREEMENT WITH RESPECT TO LIABILITIES TO THIRD

PARTIES, NEITHER PARTY SHALL BE LIABLE FOR CONSEQUENTIAL, INCIDENTAL,

PUNITIVE, EXEMPLARY OR INDIRECT DAMAGES, LOST PROFITS OR OTHER BUSINESS

INTERRUPTION DAMAGES, BY STATUTE, IN TO RT OR CONTRACT, UNDER ANY INDEMNITY PROVISION OR OTHERWISE. IT IS THE INTENT OF THE PARTIES THAT THE

LIMITATIONS HEREIN IMPOSED ON REMEDIES AND THE MEASURE OF DAMAGES BE

WITHOUT REGARD TO THE CAUSE OR CAUSES RELATED THERETO, INCLUDING THE

NEGLIGENCE OF AN Y PARTY, WHETHER SUCH NEGLIGENCE BE SOLE, JOINT OR CONCURRENT, OR ACTIVE OR PASSIVE. TO THE EXTENT ANY DAMAGES REQUIRED TO

BE PAID HEREUNDER ARE LIQUIDATED, THE PARTIES ACKNOWLEDGE THAT THE

DAMAGES ARE DIFFICULT OR IMPOSSIBLE TO DETERMINE, OR OTHERWISE OBTAINING

AN ADEQUATE REMEDY IS INCONVENIENT AND THE DAMAGES CALCULATED HEREUNDER CONSTITUTE A REASONABLE APPROXIMATION OF THE HARM OR LOSS.

THE PARTIES FURTHER AGREE THAT PAYMENT OF SUCH AMOUNT SHALL BE

LIQUIDATED DAMAGES AND NOT AS A PENALTY, AND IS THEREFORE NOT SUBJECT TO AVOIDANCE UNDER CALIFORNIA CIVIL CODE SECTION 1671.

15. Assignment.

15.1 When Consent Required. Except as specifically provided herein, neither Party shall transfer or assign this Agreement or its rights hereunder, without the prior written consent of the other Party, which consent may not be unreasonably withheld, conditioned or delayed. Either Party may, without the consent of the other Party (and without relieving itself from any liabilities hereunder that arose prior to the date of such transfer unless assumed by the assignee) transfer or assign this Agreement or its rights hereunder: (i) to an Affiliate of such Party, or (ii) to any Person succeeding to all or substantially all of the assets of such Party; provided that the assignee assumes all of assignor’s obligations; provided that such assignee assumes in writing all of assignor’s obligations hereunder at least from and after the date of such assignment or transfer, and agrees to be bound by this Agreement.

15.2 Binding Effect. Subject to the foregoing, this Agreement shall benefit and be binding on the permitted successors and assigns of the Parties hereto. Any assignment or transfer not made in compliance with these provisions shall be null and void and of no force or effect.

16. Confidentiality.

16.1 Nondisclosure of Confidential Information. The Party receiving Confidential Information (the “ Receiving Party ”) from the other Party (the “ Disclosing Party ”) shall not disclose Confidential Information to a t hird party (other than the Party’s officers, employees, directors, lenders (including potential lenders), counsel, accountants, or advisors, or any such Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

15 representatives of a Party’s Affiliates, who have a need to know such information and have agreed to keep such terms confidential as provided herein) except in order to comply with any applicable Law, regulation, or any exchange, control area or independent system operator rule or in connection with any court or regulatory proceeding applicable to such Party or any of its Affiliates; provided, each Party shall use commercially reasonable efforts to prevent or limit the disclosure.

The Parties shall be entitled to all remedies available at law or in equity to enforce, or seek relief in connection with, this confidentiality obligation.

16.2 Public Records Act. The Parties acknowledge and agree that this Agreement and the transactions hereunder are subject to the requirements of the California Public Records Act (Government Code Section 7920 et seq.) and the Ralph M. Brown Act (Government Code Section 54590, et seq.). Upon either Party’s receipt of a request or demand from any Person not a Party hereto pursuant to the California Public Records Act for production, inspection and/or copying of Confidential Information (“Requested Confidential Information”), the Party receiving the request shall promptly notify the other in writing via email that such request has been made.

Either Party shall have the right to take, at its sole expense, whatever legal steps are necessary to prevent release of the Requested Confidential Information to such Person by the other Party.

If either Party takes no such action within a reasonable period of time after receiving the foregoing notice either Party may, in its discretion, comply with such third -party request or demand and is not required to defend against it. If either Party does take or attempt to t ake such action, the Parties shall cooperate in a timely manner to prevent the release of the Requested Confidential Information.

16.3 Injunctive Relief. Each Party acknowledges that its obligations hereunder as Receiving Party are necessary and reasonable in order to protect Disclosing Party and Disclosing Party’s business, and expressly acknowledges that monetary damages would be inadequate to compensate Disclosing Party for any breach or threatened breach by Receiving Party of any covenants and agreements set forth herein. Accordingly, each Party acknowledges that any such breach or threatened breach by it as Receiving Party will cause irreparable injury to Disclosing Party and that, in addition to any other remedies that may be available, in law, in equity or otherwise, Disclosing Party will be entitled to obtain injunctive relief against the threatened breach of this Agreement or the continuation of any such breach, without the necessity of proving actual damages.

16.4 Press Releases. Neither Party shall issue a press release regarding the transactions contemplated by this Agreement unless both Parties have agreed upon the contents of any such public statement.

17. Notices. All notices required to be given under this Agreement shall, except as otherwise provided herein, be in writing and shall be sent by prepaid mail or overnight courier addressed to the respective Party at the addresses listed in Exhibit C or to such other address as may designated hereafter by a Party in writing by like notice from time to time. Any notice delivered after 5:00 p.m. Pacific Time on a Business Day shall be deemed to have been delivered on the following Business Day.

18. General.

18.1 Governing Law. This Agreement shall be governed by, construed under and enforced in accordance with the laws of the State of California without regard to principles of conflicts of law. The venue for any court action brought pursuant to this Agreement shall be Sacramento, California.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

16 18.2 Counterparts. This Agreement may be executed in any number of counterparts, each of which shall be deemed an original, but all of which shall consti tute one Agreement after each Party has signed at least one counterpart, and the Parties have exchanged signed counterparts. The exchange of copies of this Agreement and of signature pages by facsimile transmission, in portable document format (pdf) or by other electronic means shall constitute effective execution and delivery of this Agreement and may be used in lieu of the original Agreement for all purposes.

18.3 Entire Agreement. Together with the O&M Agreement and the Site Agreement and the respective exhibits attached thereto, this Agreement and the Exhibits attached hereto constitute the entire agreement and understanding between CDWR and ROSEVILLE with respect to the subject matter hereof and supersedes all prior agreements relating to the subject matter hereof, which shall be of no further force or effect. The Exhibits attached hereto are integral parts of this Agreement and are made a part of this Agreement by reference. To the extent that any provision of this Agreement or any paragraph, term, sentence, phrase, clause or word of this Agreement shall be found by a court of law having jurisdiction to be void, illegal or unenforceable for any reason, the Parties shall meet to determine whether this Agreement can fulfill the objectives of each Party notwithstanding such ruling. If either Party de termines that this Agreement can no longer fulfill its objectives under such ruling, then either Party may terminate this Agreement. Otherwise, such paragraph, term, sentence, phrase, clause or word shall be deemed modified or deleted in such a manner as to make the Agreement, as so modified, legal and enforceable under applicable Laws. The remainder of the Agreement shall remain in full force and effect. This Agreement does not create, modify, or diminish any ownership or property rights, nor creates an y easements or rights of entry, except as set forth explicitly in this Agreement.

18.4 Amendments. This Agreement may only be amended by an instrument in writing duly executed by ROSEVILLE and CDWR.

18.5 No Waiver. No waiver of either Party of an Event of Default by the other Party, nor any election to exercise or not exercise any rights following an Event of Default, shall constitute a waiver by such Party of any subsequent Event of Default by the other Party, whether similar or dissimilar, or of any remedy with respect thereto.

18.6 No Partnership. Nothing herein is intended to create or is to be construed as creating a joint venture, partnership, agency or other similar relationship between the Parties other than that of contracting parties as set forth in this Agreement. The rights and obligation s of the Parties hereunder shall be independent of one another and shall be limited to those expressly set forth herein.

18.7 Third Party Beneficiaries. This Agreement is for the benefit of the Parties hereto and is not intended to be for the benefit of any third party except their respective Affiliates and Lenders of the Parties to the extent expressly set forth herein.

18.8 Joint Efforts. The Parties acknowledge and agree that each Party and its counsel have read this Agreement in its entirety, fully understand it and accept its terms and conditions.

This Agreement shall be considered for all purposes as prepared through the joint efforts of the Parties and shall not be construed against one Party or the other as a result of the preparation, substitution, submission or other event of negotiation, drafting or execution hereof.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

17 18.9 Further Assurances. Upon the receipt of a written request from the other Party, each Party shall execute such additional documents, instruments and assurances and take such additional actions as may be reasonably requested by the other Party which are consistent with the provisions of this Agreement and which do not involve the assumptions of obligations other than those provided for in this Agreement, to give full effect to this Agreement and to carry out the intent of this Agreement.

18.10 Conflict in Agreements . The Parties agree that any conflict between this Agreement and the Site Agreement shall be resolved in favor of the Site Agreement.

* * * * *

IN WITNESS WHEREOF, the City of Roseville, a municipal corporation, has authorized the execution of this Agreement in duplicate by its City Manager and attested to by its City Clerk under the authority of Resolution No. _________, adopted by the Council of the City of Roseville on the ___ day of ____________, 2025, and the CALIFORNIA DEPARTMENT OF WATER RESOURCES represents that it has caused this Agreement to be duly executed.

CITY OF ROSEVILLE, a CALIFORNIA DEPARTMENT OF
municipal corporation WATER RESOURCES

BY: ____________________________ BY:

DOMINICK CASEY DELPHINE HOU
City Manager Deputy Director, Statewide Energy

ATTEST:

By: ___________________________

SONIA OROZCO
City Clerk

APPROVED AS TO FORM: APPROVED AS TO FORM AND LEGAL
SUFFICIENCY:

BY: ____________________________ BY: ________________________ MICHELLE SHEIDENBERGER COLIN A. WOOD
City Attorney Attorney IV

APPROVED AS TO SUBSTANCE:

BY: __________________________

DAN BEANS
Electric Utility Director
Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

18 Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

19 EXHIBIT A

SCOPE OF SERVICES

O&M CONTRACTOR SHALL PERFORM EACH OF THE SERVICES LISTED IN THIS

EXHIBIT A IN ACCORDANCE WITH THE STANDARDS REQUIRED UNDER SECTION

3.2 OF THE AGREEMENT.

The specific obligations of the O&M Contractor will depend on the Additional Units.

The following provisions are illustrative and are provided to identify some of the possible areas of coverage and show the level of detail that may be appropriate.

I. Programs
A. In addition to those responsibilities described in the Agreement, O&M Contractor shall be responsible for completing Preventative Maintenance (PM) activities as outlined and assigned in Table 1 below related to the Project.

1. Perform, document, and report on Items in Table 1 identified to be completed by O&M Contractor.

2. Perform tasks in Item A using qualified staff.

3. Arrange for and facilitate the completion of Items in Table 1.

4. Prepare supporting documentation, emission dat a, meter readings , and similar information necessary to to perform in accordance with the Site Agreement and Exhibit G thereto (“Dispatch Protocol”).

5. Extend O&M Contractor’s Safety Program and requirements to include the Operation and Maintenance of the Project.

6. Provide periodic reporting as required by the Site Agreement and Exhibit G thereto..

7. Extend O&M Contractor’s security program for maintaining the security of the Project and surrounding area.

II. Project Preservation
A. Table 2 in this Exhibit shall be adhered to in order to maintain the operational availability and readiness of the Project because of potential infrequent dispatch of the Project.

III. Specific Requirements
A. O&M Contractor's scope of Services is based on the Project design as described in the different Project Agreements, the Project Operations and Maintenance Manuals, vendor manuals and design drawings. O&M Contractor will follow these documents when operating and maintaining the Project.

B. O&M Contractor, as part of the Services, is responsible for:

1. Providing such trained personnel as is reasonably necessary to operate and maintain the Project and provide the Services set forth in this Agreement.

2. Operating and maintaining the Project in accordance with the Pro ject Operations and Maintenance Manual.

3. Planning and managing on -site operations and maintenance activities, following Good Industry Practice.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

20 4. Assuring that the Project is operated in accordance with this Agreement and in a safe, reliable, efficient, and prudent manner.

5. Assuring that operations and maintenance personnel are trained and qualified for their assigned responsibilities and tasks, and that such qualification is maintained.

6. Assuring that the Project meets contract, regulatory, and environmental requirements and subject to the exceptions set forth in the Project Agreements or otherwise identified by Owner or O&M Contractor.

7. Managing and controlling costs consistent with budget requirements , consistent with the allowances set forth in the Agreement.

8. Planning, scheduling and managing work and maintenance activities.

9. [RESERVED].

10. Establishing labor relations and personnel programs that will meet state and federal requirements.

11. Maintaining a current inventory of Owner provided spare parts and materials. O&M Contractor will identify required items, cost, quantity and need date.

12. Managing outages, both planned and forced outages, by using detailed and integrated plans and schedules, and resource management.

13. Performing certain tasks, duties, responsibilities and obligations assigned to Owner under the Interconnection Agreements, including, but not limited to, the following:
a. Providing the System Operator and Owner with all required information regarding the Project's availability for generating , as required by the Site Agreement and Exhibit G thereto.
b. Responding to dispatch orders from the System Operator and Owner, subject to applicable NERC, WECC, BANC, and CAISO restrictions and requirements.
c. Monitoring and adjusting the reactive output of the generators t o maintain transmission voltage levels within the capability of the Project's generators.
d. Responding to and correcting generator dynamic instability in accordance with instructions from the System Operator.

14. Oversight of periodic corrective maintenance ("CM ") activities in accordance with Good Utility Practice to troubleshoot, inspect, and repair the equipment upon identification and detection of certain conditions, including without limitation to ensure operational availability of the Project. a. Physical fault conditions such as:

A) Blocked / stopped flow
B) Fractures / break / breaches
C) Cracks
D) Distortion / displacement
E) Corrosion / discoloration
b. Out of specification conditions such as:

A) High / low flow, pressure, temperature, or chemistry B) Off voltage
Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

21 C) Out of limits / adjustments
D) Erratic output
E) Intermittent / spurious operation
F) Failure to control / hold
G) High / low output
H) Improper timing
c. Demand fault conditions such as failure to:

A) Start / run / operate
B) Stop
C) Open
D) Close
E) Move / release / respond
d. Abnormal characteristics such as:

A) Overheating
B) Noise
C) Vibration
D) Chatter
E) False response
e. Leakage conditions such as:

A) Leakage to surrounding environment
B) Leakage past seats / stems / packing / seals
f. CM activities not requiring equipment shutdown shall be performed as soon as possible and in order of priority. CM activities requiring equipment shutdown shall be performed when equipment is removed from service.
g. CM activities and preventive maintenance will be performed on a system-by-system basis and shall be according to Table 1

15. Performing such other tasks and services within the scope of the Project Agreements which Owner may reasonably request from time to time in connection with operation of the Project.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

TABLE 1: TM2500 MAINTENANCE QUICK REFERENCE

SYSTEM INSPECTED ITEM INSPECTION FREQUENCY RESPONSIBLE PARTY

REMARKS
Auxiliary System On-Engine Electrical
Harnesses & Cables
• First 500 Hours
• Annually
GE • Check for security.
• Check ignition leads and thermocouple harness for burning or chafing.

Auxiliary System Temperature Sensors (RTDs) • First 500 Hours • 1000 Hours
• Annually
GE • Visually inspect the element. Ensure element is not damaged. • Function check with a calibrated meter. If temperatures observed seem to be incorrect:
• Replace element and seals whenever variation in the controlled temperature is noticed. • Inspect and clean engine cable connectors with contact cleaner. • Tighten cable connectors.
• Replace on component failure.

Auxiliary System On-Engine Thermocouple
Temperature Elements • First 500 Hours
• 1000 Hours
• Annually
GE • Visually inspect the element. Ensure element is not damaged. • Function check with a calibrated meter. If temperatures observed seem to be incorrect:
• Replace element and seals whenever variation in the controlled temperature is noticed. • Inspect and clean engine cable connectors with contact cleaner. • Tighten cable connectors.
• Replace on component failure.

Auxiliary System Flow Control Valve (VSV) • Annually GE • Inspect/verify proper operation per manufacturer recommendations.

Auxiliary System Linear Variable differential
Transformers (LVDT)
• Annually GE • Visually inspect for any damage.
• Verify operation. LVDT feedback should at least be verified at 0% and 100%. • Verify the actual position versus the control position.

Auxiliary System Turbine Speed Elements • Semi-Annually • Annually GE Semi-Annually
• As per table 11-2 in the engine manual, test the redundant overspeed protection by simulating and confirm functionality of system.

Annually
• Visually inspect the element to ensure it is not damaged. • Measure for any shorts between the signal common and the shield that could create ground loops and induce noise. • Ensure that the noise level remains in accordance with the specification by which it is designed. If the sensor does not perform within the specified limits, send to repair.

Auxiliary System Turbine Ignitor(s) and
Exciter(s)
• Annually
GE • Check for moisture or other contaminants on the terminal where the lead and plug couple. • Exciters are designed to require little or no maintenance. • An ignition exciter often lasts to engine overhaul.
• Ignitor plug inspections consist of a simple distance measurement from the plug shell to the center electrode. • • The amount of shell material necessary to survive between scheduled inspection periods is determined by the engine and plug manufacturers. When this gap limit is reached, the plug should be replaced.

Auxiliary System Pressure Transmitters (PTs) • Annually GE • Visually inspect to ensure it is not damaged.
• Ensure transmitter is free of moisture.
• Ensure electrical connections are not damaged.
• Calibrate per manufacturer recommendation. Set zero and span to 4 and 20 mA at required pressures. Can be calibrated more often if drift occurs.•
• If malfunction is suspected, verify that the hardware and process connections are in good working order. • • If the unit is still malfunctioning, refer to the manufacturer maintenance and troubleshooting manual for further instructions.

Auxiliary System Turbine Flame Detectors • Annually GE • The flame sensor output will deteriorate as the lens becomes dirty. It is recommended, when initially installed, that the signal level be recorded during normal operation. During subsequent running, the signal level should be compared with the initial values. If a significant reduction in the signal level is noticed, then it is recommended that the lens be cleaned at the next opportunity, with the turbine shut down and cold. • Clean the lens with isopropyl alcohol or other residue free solvent compatible with sapphire. • In order to reduce the risk of galling, an anti-seize (refer to engine O&M for approved type) compound should be applied to the mounting thread prior to reinstallation of the sensor.
• The UV flame detectors can be tested with a lighter. • Replace on component failure.

Control System PLC Batteries • Semi-Annually GE • Ensure LED is Green. If not replace batteries.

Control System Electrical Connections • Annually GE • Generally inspect for condition and tighten any loose connections.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

Dual Fuel with Water
Injection System
Ball Valves • Annually GE • Check valve body for leakage. • If leakage occurs, tighten the valve connections or fasteners. • If valve is damaged or fails, replace valve.

Dual Fuel with Water
Injection System
Globe/Instrument Valves • Annually GE • Check valve stem for leakage. • If valve is damaged or fails, replace valve.
• Inspect more often if repeated problems occur.

Dual Fuel with Water
Injection System
Pressure Relief Valves • Annually GE • Check valve stem for leakage. • If valve is damaged or fails, replace valve.
• Inspect more often if repeated problems occur.

Dual Fuel with Water
Injection System Gas Fuel/Liquid Fuel Filter • Daily O&M Contractor • Replace on differential pressure as required.

Dual Fuel with Water
Injection System
Pressure Differential
Transmitters
(PDTs)
• Annually
GE • Visually inspect to ensure it is not damaged.
• Ensure transmitter is free of moisture.
• Ensure electrical connections are not damaged.
• • Calibrate per manufacturer recommendation. Set zero and span to 4 and 20 mA at required pressures. Can be calibrated more often if drift occurs.
• If malfunction is suspected, verify that the hardware and process connections are in good working order. • If the unit is still malfunctioning, refer to the manufacturer maintenance and troubleshooting manual for further instructions.

Dual Fuel with Water
Injection System Pressure Transmitters (PTs) • Annually GE • Visually inspect to ensure it is not damaged.
• Ensure transmitter is free of moisture.
• Ensure electrical connections are not damaged.
• Calibrate per manufacturer recommendation. Set zero and span to 4 and 20 mA at required pressures. Can be calibrated more often if drift occurs. • If malfunction is suspected, verify that the hardware and process connections are in good working order. • If the unit is still malfunctioning, refer to the manufacturer maintenance and troubleshooting manual for further instructions.

Dual Fuel with Water
Injection System
Flow Transmitter and Meters • Annually GE • Visually inspect to ensure it is not damaged. • Ensure transmitter is free of moisture.
• Ensure electrical connections are not damaged.
• • Calibrate per manufacturer recommendation. Set zero and span to 4 and 20 mA at required pressures. Can be calibrated more often if drift occurs.
• If malfunction is suspected, verify that the hardware and process connections are in good working order. • If the unit is still malfunctioning, refer to the manufacturer maintenance and troubleshooting manual for further instructions.

Dual Fuel with Water
Injection System
Solenoid Operated Valves
(SOVs)
• Annually
GE • Ensure valve is not leaking or damaged.
• If leak occurs, tighten connections as necessary and ensure electrical connection are tight with no damage.

Dual Fuel with Water
Injection System
Temperature Sensors (RTDs) • Annually GE • Visually inspect the element. Ensure element is not damaged. • Function check with a calibrated meter. If temperatures observed seem to be incorrect:
• Replace element and seals whenever variation in the controlled temperature is noticed. • Inspect and clean engine cable connectors with contact cleaner. • Tighten cable connectors.
• Replace on component failure.

Dual Fuel with Water
Injection System
Gas and Liquid Fuel Flow
Control Valve
• Annually GE
• Calibrate as per manufacturer instructions.
• If malfunction is suspected, verify that the hardware and process connections are in good working order. • If the unit is still malfunctioning, refer to the manufacturer maintenance and troubleshooting manual for further instructions. • Ensure meter assembly is not damaged or leaking.
• Ensure electrical connections are not damaged.
• If plugs are removed, sensor case should be re purged with dry inert gas. • Lubricate the ball screw and bearing in accordance with the manufacturer installation and operation manual.

Dual Fuel with Water
Injection System
Gas and Liquid fuel Flow
Control Valve • 6 Years GE • Complete remanufacture (overhaul).

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

Dual Fuel with Water
Injection System Pressure Safety Valve • Annually GE • Inspect for damage. • Replace if released.

Dual Fuel with Water
Injection System

Check Valves
• Annually GE • Check valve body for leakage.
• If leakage occurs, tighten the valve connections or fasteners. • If valve is damaged or fails, replace valve.

Dual Fuel with Water
Injection System
Liquid Fuel Strainer • Semi-Annually GE • Ensure strainer is not clogged, or damaged. • • Check for pressure loss across strainer. If pressure loss or clogging is observed, remove access cover and clean strainer. Replace o-ring if necessary and re-install strainer and access cover.
• Clean strainer, and ensure strainer is free from debris. • Ensure strainer is not leaking after replacement.

Dual Fuel with Water
Injection System
Butterfly Valves • Annually GE • Ensure valve is not leaking or damaged. • If leakage occurs, tighten the valve connections or fasteners. • Inspect and verify proper operation.

Dual Fuel with Water
Injection System Liquid Fuel Motor & Pump • Refer to TP2010 O&M Contractor • Greasing inspection and storage requirements to be followed as per TP2010.

Dual Fuel with Water
Injection System Water Injection Motor &
Pump
• Refer to TP2010 O&M Contractor • Greasing inspection and storage requirements to be followed as per TP2010.

Dual Fuel with Water
Injection System

Pressure Control Valves
• Annually GE • Ensure the pressure regulator is not damaged or leaking. • Calibrate per manufacturer recommendation.
• Ensure the valve is not damaged and the seat is not leaking. • Examine settings against manufacturer’s standard.
• Inspect and verify proper operation.

Dual Fuel with Water
Injection System Engine
Related

General Conditions
• Daily O&M Contractor
• General appearance and integrity of unit.

Dual Fuel with Water
Injection System Engine
Related

Engine Plumbing
• 500 hours GE
• Check fuel and oil plumbing line to and on engine for security, chafing, and leaks.

Dual Fuel with Water
Injection System Engine
Related

Fuel Filters • Quarterly
• As required by Delta P
O&M Contractor • Check for cleanliness and damage.
• Replace on Delta P.

Dual Fuel with Water
Injection System Engine
Related

Turbine First Stage
• Semi-Annually GE
• Inspect at 500 hours, then 4000 hours or 6 months.

Dual Fuel with Water
Injection System Engine
Related

Combustor
• Semi-Annually GE
• Maintenance findings will determine if Level III maintenance is needed.

Dual Fuel with Water
Injection System Engine
Related

Mount/Skid/Piping Valves
• Semi-Annually GE
• Check for leaks, cracks and proper alignment.

Fire and Gas Protection
System Gas Sensors • Monthly O&M Contractor • Calibrate Fire and Gas Protection
System Aerosol Canister • Semi-Annually GE • Inspect as per instructions included in this supplement.

Fire and Gas Protection
System
Backdraft Damper (part of
ventilation fan) • Semi-Annually GE • Inspect and ensure damper fully closes when the ventilation fan is not running.

Fire and Gas Protection
System Visual/Audio Alarm • Semi-Annually GE • Test

Fire and Gas Protection
System Thermal Spot Detectors • Semi-Annually GE • Inspect Fire and Gas Protection
System Manual Pull Stations • Semi-Annually GE • Test functionality (with system disabled).

Fire and Gas Protection
System IR Gas Sensors • Semi-Annually GE • Calibrate
Generator Generator Frame • Monthly O&M Contractor • Conduct general inspection.

Generator Grounding System • Monthly O&M Contractor • Verify shaft and frame grounding.

Generator Vibration Signatures • Daily O&M Contractor • Check Bently Nevada gauges for measuring vibration.

Generator Oil Pump Coupling • Annually GE • Inspect
• Note: This is a dry coupling and no grease is required. Check axial play according to generator manual.

Generator Bearings • Annually GE • Maintenance level dependent on findings.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

Generator Bearing Insulation • Annually GE • Check resistance.

Generator Stator Core After 1st year of operation
After 3rd year of operation GE • Check air-gap side for shorts between laminations.

Generator

Stator Winding • After 1st year of operation
• After 5th year of operation
GE • Check winding, insulation, and take measurements of resistance. • Verify radial wedge tightness.
• Perform hi -pot tests.

Generator Generator Inspection • 50,000 HRS GE • Perform in accordance with Generator Operation and Maintenance Manual.

Generator Generator Inspection • 100,000 HRS GE • Perform in accordance with Generator Operation and Maintenance Manual.

Generator Lube Oil
System Lube Oil • Semi-Annually GE • Have oil samples analyzed.

Generator Lube Oil
System Lube Oil Level • Weekly O&M Contractor • Check reservoir sight gauge.

Generator Lube Oil
System Bearing Drains • Weekly O&M Contractor • Check that flow is maintained.

Generator Lube Oil System

Filter
• Semi-Annually
• As required by Delta P
GE • Inspect filter element every six months or sooner if required. • Have ample supply of spare elements.
• If external leakage is noted, replace O-ring or bonded seal at leak. For bowl seal leaks, replace O-ring seal. If leakage persists, check sealing surfaces for scratches or cracks and replace any defective parts.
• Differential pressure devices indicate when the element needs changing or because of high fluid viscosity in "cold start" conditions.

Generator Lube Oil
System Tank Level Transmitter • Annually GE • Calibrate as necessary. Replace component if defective or fails. Calibrate at Least Once a Year (more often if drift occurs).

Generator Lube Oil
System
Thermostatic 3-Way Control
Valve • Annually GE • Replace thermostatic element and seals whenever some variation in the controlled temperature is noticed. More often if repeated problems occur.

Generator Lube Oil
System DC Pump Relief Valve • Annually GE • Check valve stem for leakage. If valve is damaged or fails, replace valve. More often if repeated problems occur.

Generator Lube Oil System Tank Heater -
Thermostatically Controlled
Heater
• Semi-Annually GE • Check heaters for coatings and corrosion. Clean if necessary. • Check tank for sediment around the heater and remove as necessary. • • Check heater and tank for accumulated sludge deposits and remove if necessary. Inspect for loose or corroded terminal connections/ends. • If corrosion is found, check box gasket and replace as necessary. • Check conduit layout to correct conditions that allow corrosion to enter terminal housing.

Generator Lube Oil
System Tank Level Gauge • Annually GE • Replace component if damaged or fails.

Generator Lube Oil System
Tank Fill Cap and Strainer

• Annually
GE • • Inspect filler cap for missing parts which would prevent cap from sealing and allow water or contaminates to enter tank. Replace missing parts as needed. More often if repeated problems occur.
• Remove access cover and clean strainer. Replace o-ring if necessary and re-install strainer and access cover.

Generator Lube Oil
System Suction Strainer - Basket • Quarterly O&M Contractor • Check for pressure loss across strainer. If pressure loss or clogging is observed, remove access cover and clean strainer. Replace o-ring if necessary and re-install strainer and access cover.

Generator Lube Oil System
Tank Air/Oil Separator

• Weekly
O&M Contractor • • Check differential gauge filter element should be replaced when the differential pressure gauge reads 3” WC, per manufacturer guidelines. • Replace component if damaged or fails.

Generator Lube Oil System
Check Valves

• Annually
GE • Check valve for stem seal leakage.
• If leaking, tighten packing gland nuts until leakage stops. If valve is damaged or fails, replace valve. • More often if repeated problems occur.

Generator Lube Oil System
Ball Valves

Generator Lube Oil System
Cooler Drain/Vent Valve

Generator Lube Oil System
Instrument Valves
• Annually
GE • Check valve for stem seal leakage.
• If leaking, tighten packing gland nuts until leakage stops. If valve is damaged or fails, replace valve. • More often if repeated problems occur.

Generator Lube Oil
System Flow Indicator • Annually GE • Replace component if damaged or fails.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

Generator Lube Oil System

Temperature Sensors (RTDs)

• Annually
GE • Visually inspect the element. Ensure element is not damaged. • Function check with a calibrated meter. If temperatures observed seem to be incorrect:
• Replace element and seals whenever variation in the controlled temperature is noticed. • Inspect and clean engine cable connectors with contact cleaner. • Tighten cable connectors.
• Replace on component failure.

Generator Lube Oil
System DC Pump Coupling • Annually GE • If coupling is defective or fails, replace coupling.

Generator Lube Oil System
Pressure Control Valve

• Annually
GE • Inspect for damage or leaking.
• If leaking is found, repair in accordance with manufacturer recommendations. • Inspect more often if repeated problems occur.

Generator Lube Oil
System DC Pump • Annually GE • Protect pump from freezing temperatures. Ensure motor is lubricated as per TP2010.

Generator Lube Oil
System Tank • Annually GE • Replace component if damaged or fails.

Generator Lube Oil
System Orifice Plates • Annually GE • Replace if component is damaged or fails.

Generator Lube Oil System Pressure Differential
Transmitters
(PDTs)
• Annually
GE • Visually inspect to ensure it is not damaged.
• Ensure transmitter is free of moisture.
• Ensure electrical connections are not damaged.
• • Calibrate per manufacturer recommendation. Set zero and span to 4 and 20 mA at required pressures. Can be calibrated more often if drift occurs.
• If malfunction is suspected, verify that the hardware and process connections are in good working order. • If the unit is still malfunctioning, refer to the manufacturer maintenance and troubleshooting manual for further instructions.

Generator Lube Oil System Pressure Transmitters (PTs) • Annually GE • Visually inspect to ensure it is not damaged.
• Ensure transmitter is free of moisture.
• Ensure electrical connections are not damaged.
• • Calibrate per manufacturer recommendation. Set zero and span to 4 and 20 mA at required pressures. Can be calibrated more often if drift occurs.
• If malfunction is suspected, verify that the hardware and process connections are in good working order. • If the unit is still malfunctioning, refer to the manufacturer maintenance and troubleshooting manual for further instructions.

Hydraulic Starter System
MOT-6015 Hydraulic Starter
Motor
• Quarterly
• As per TP2010
O&M Contractor • Monitor oil temperature. Lubricate bearing (see placard with precise instructions at the pressure -feed lubrication nipples). • Renew grease in the bearings in accordance with TP2010.

Hydraulic Starter System SOV-6019 Hydraulic Pump
SOV Actuater • Quarterly O&M Contractor • Check hoses for damage or aging. Replace if defective.

Hydraulic Starter System Low Pressure Return Filter • Weekly • Annually
• As required
O&M Contractor • Check visual indicators on both sides of filters. If indicator is activated, replace filter element. • Replace filter on a regular basis and once a year regardless of visual indication.

Hydraulic Starter System Hose Assemblies • Quarterly O&M Contractor • Check hoses for damage or aging. Replace if defective.

Hydraulic Starter System Starter Motor Assembly • Semi-Annually GE • Keep both interior and exterior of the motor free from dirt, water, oil, and grease. • Motors operating in dirty places should be periodically disassembled and thoroughly cleaned. • Check to see that all bolts and nuts are tightened securely.

Hydraulic Starter System Charge Pump Filter Element • Weekly • Annually
• As required
O&M Contractor • Check visual indicator weekly.
• Replace filter on a regular basis and replace filter once a year regardless of visual indicator indication.

Hydraulic Starter System Main System Pressure Gauge • Annually GE • Check for broken glass, replace if necessary. • Disassemble and oil moving components with high grade instrument oil.

Hydraulic Starter System Charge Pump Pressure
Gauge
• Annually GE • Check for broken glass, replace if necessary. • Disassemble and oil moving components with high-grade instrument oil.

Hydraulic Starter System Starter Clutch Temp Element
• Annually
GE • Visually inspect the element. Ensure element is not damaged. • Function Check with a calibrated meter. If temperatures observed seem to be incorrect:
• Replace element and seals whenever variation in the controlled temperature is noticed. • Inspect and clean engine cable connectors with contact cleaner. • Tighten cable connectors.
• Replace on component failure.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

Low Voltage AC/DC
System Batteries • Quarterly O&M Contractor • Inspect and ensure connections are clean. • Fill or replace as needed in accordance with manufacturer recommendations.

Low Voltage AC/DC
System General • Annually GE • Generally inspect all system components. Replace or repair as needed.

Trailers Hoses and Cables • 5 Years • Inspect hoses and cables in the beam of the trailers for any signs of wear or damage repair and replace as necessary.

Trailers Locking Pins • Annually • Inspect for corrosion and ensure locking pin moves freely. • Grease if necessary.

Trailers Electrical Cable Ends • Annually • Inspect for damage, deterioration or corrosion. • Keep protected from the elements.

Trailers Split and Air Line Couplings • Annually • Inspect for damage, deterioration or corrosion. • Keep protected from the elements.

Trailers All bushings (cams, lack
adjusters) • Monthly • Grease as per manufacturer recommendations.

Trailers Brake Lining • 3 Months • Minimum thickness not to be less than 7mm.

Trailers Tires • Monthly • Use a tire gauge to confirm correct pressure.

Trailers

Paintwork

• 3 Months
• Check for signs of corrosion. If damage to the paintwork cannot be rectified immediately, apply a thin layer of engine oil to the damaged areas as a temporary measure.
• Repair according to TS-95953 Paint Specification, Application of Paint and Protective Coatings.

Trailers

Wheel Nuts
• After First 50 km
• After First 150 km
• Every 3 Months

• Wheel nuts be tightened to the recommended torque setting (also after every wheel change).

Trailers Wheel Bearings • After First Month
• Annually • Check play on wheel bearings
Trailers Threaded Connections • After First Month
• Every 3 Months • All threaded connections to be checked and tightened to correct torque setting.

Trailers Brake System • After First Month
• Before Re-transportation
• Check brakes for correct adjustment and efficiency (roller test). • Have the ABS system inspected and check for possible damage or wear to the cables.

Trailers Air Bellows • Every 3 Months • Check air bellows or compensation cylinders for air leaks, damage, and dirt.

Trailers Hydraulic System • Every 3 Months • Check hydraulic steering system (cylinders, rods, rotating elements and lines) for leaks, damage and dirt.

Trailers Hydraulic System • Upon Installation Completion • Ensure hydraulic oil tanks of the Turbine and Generator trailers are fully topped off and add a high quality anti rust inhibitor for use with hydraulic oil.

Trailers Tires • Annually
• Upon Installation Completion
• Protect tires from sun damage. Inspect for deterioration and if necessary replace before re-transportation of the package.

Trailers Air system • Annually • Inspect for deterioration.

Trailers Lighting System • Annually • Inspect cables for deterioration and repair as necessary.

Turbine Enclosure Paintwork • After First Month
• Every 3 Months
O&M Contractor • Enclosure ceiling coating maintenance, if necessary, shall be made in accordance with the latest revision TP2118 Instruction
Turbine Lube Oil System Supply and Scavenge Filters • Semi-Annually GE • Inspect filter element every six months or as necessary. • Ensure an ample supply of spare elements.
• Ensure filter is not leaking.
• Replace on Differential Pressure ( DP).

Turbine Lube Oil System Thermostatic Control Valve • Annually GE • Ensure element is not damaged. • Replace the thermostatic element and seals whenever some variation in the controlled temperature is noticed.

Turbine Lube Oil System Tank Level Transmitter • Semi-Annually GE • Visually inspect to ensure it is not damaged.
• Ensure transmitter is free of moisture.
• Ensure electrical connections are not damaged.
• • Calibrate per manufacturer recommendation. Set zero and span to 4 and 20 mA at required pressures. Can be calibrated more often if drift occurs.
• If malfunction is suspected, verify that the hardware and process connections are in good working order. • If the unit is still malfunctioning, refer to the manufacturer maintenance and troubleshooting manual for further instructions.

Turbine Lube Oil System Relief Valves • Annually GE • Ensure the valve is not damaged, and the seat is not leaking.

Turbine Lube Oil System Tank • Annually GE • Check tank for leaks and damage. • Ensure vents are free from debris.

Turbine Lube Oil System
Clutch Drain Return Strainer • Semi-Annually GE • Ensure strainer is not damaged. • Ensure strainer is free from debris and magnets are intact. • Ensure strainer is not leaking.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

Turbine Lube Oil System Tank Heater • Annually GE • Check heaters for coatings and corrosion; clean if necessary. • Check for loose terminal connections and tighten as necessary. • The tank should be checked regularly for sediment around the heater. • Check thermostat for proper setting.
• If adjustment is required, remove cover and calibrate per manufacturer recommendation.

Turbine Lube Oil System VGV Pump Filter Element • Semi-Annually GE • Replace filter element every six months or as necessary. • Ensure an ample supply of spare elements.
• Ensure filter is not leaking.

Turbine Lube Oil System Level Gauge • Annually GE • Ensure the glass is free of scratches, chips or damage. • Ensure the connections are not leaking.
• Ensure inside of the sight glass are free of foreign material.

Turbine Lube Oil System Tank Fill Cap • Annually GE • Ensure spring will let cap automatically close. • Clean cap seal.
• Remove any spilled oil.

Turbine Lube Oil System Filler Strainer • Semi-Annually GE • Ensure strainer is not clogged, or damaged. • Clean strainer, and ensure strainer is free from debris.

Turbine Lube Oil System Tank Flame Arrestor • Annually GE • Loosen the wing nuts on the weather hood. Remove the weather hood to expose the flame arrester element. • Check the arrestor assembly for debris; ensure the passage between the individual plates is clear.

Turbine Lube Oil System Tank Demister • Weekly
• Annually O&M Contractor • Check differential gauge. • Filter element should be replaced when the differential pressure gauge reads 3” WC, per manufacturer guidelines. • Replace component if damaged or fails.

Turbine Lube Oil System Check Valves • Annually GE • Check valve body for leakage. • If leakage occurs, tighten the valve connections or fasteners. • If valve is damaged or fails, replace valve.

Turbine Lube Oil System Ball Valves • Annually GE • Check valve body for leakage. • If leakage occurs, tighten the valve connections or fasteners. • If valve is damaged or fails, replace valve.

Turbine Lube Oil System Instrument Valves • Annually GE • Check valve stem for leakage. • If valve is damaged or fails, replace valve. More often if repeated problems occur.

Turbine Lube Oil System Magnetic Chip Detectors • Annually GE • Inspect per manufactures recommendations.

Turbine Lube Oil System Relief Valves • Annually GE • Ensure the pressure regulator is not damaged or leaking. • Calibrate per manufacturer recommendation.
• Ensure the valve is not damaged and the seat is not leaking. • Examine setting against manufacturer’s standard.
• Inspect and verify proper operation.

Turbine Lube Oil System Pressure Transmitters (PTs) • Annually GE • Visually inspect to ensure it is not damaged. • Ensure transmitter is free of moisture.
• Ensure electrical connections are not damaged.
• Calibrate per manufacturer recommendation. Set zero and span to 4 and 20 mA at required pressures. Can be calibrated more often if drift occurs.

If malfunction is suspected, verify that the hardware and process connections are in good working order. • If the unit is still malfunctioning, refer to the Rosemount manufacturer maintenance and troubleshooting manual for further instructions.

Turbine Lube Oil System Pressure Differential
Transmitters
(PDTs)
• Annually GE • Visually inspect to ensure it is not damaged. • Ensure transmitter is free of moisture.
• Ensure electrical connections are not damaged.
• • Calibrate per manufacturer recommendation. Set zero and span to 4 and 20 mA at required pressures. Can be calibrated more often if drift occurs.
• If malfunction is suspected, verify that the hardware and process connections are in good working order. • If the unit is still malfunctioning, refer to the Rosemount manufacturer maintenance and troubleshooting manual for further instructions.

Turbine Lube Oil System Bubble Eliminator • Annually GE • Visually inspect to ensure it is not damaged. • Replace component if failure is suspected
Turbine Lube Oil System Hose Assemblies • Annually GE • Check hoses for leaks and replace as necessary.

Turbine Lube Oil System Hydraulic Charge Pump Filter • Semi-Annually GE • Replace filter element every six months or as necessary. • Ensure an ample supply of spare elements.
• Ensure filter is not leaking.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

Turbine Lube Oil System Temperature Sensors (RTDs) • Annually GE • Visually inspect the element. Ensure element is not damaged. • Function check with a calibrated meter. If temperatures observed seem to be incorrect:
• Replace element and seals whenever variation in the controlled temperature is noticed. • Inspect and clean engine cable connectors with contact cleaner. • Tighten cable connectors.
• Replace on component failure.

Turbine Lube Oil System TLO/HLO Heat Exchanger
Motor • Refer to TP2010 O&M Contractor • Greasing inspection and storage requirements to be followed as per TP2010.

Turbine Lube Oil System
TLO/HLO Heat exchanger
• Annually
GE • Perform inspection of the heat exchanger on a regular basis. • Check for external leaks.
• Check flow and if less than normal an internal inspection is required.

Turbine Lube Oil System Orifice Plate • Annually GE • Replace if suspected of failure Turbine Lube Oil System Accumulator • Annually
• Monthly O&M Contractor • • If there is external leakage, tighten all connections. If leakage continues, remove accumulator from system and replace faulty components. • • After original installation, check pre-charge once during first week to see that no leak has developed. Thereafter, check pre-charge monthly. • Check pre-charge if the system is acting sluggish. If pre-charge is low, check gas valve for leakage and recharge. • If there is no gas in bladder and fluid appears at gas valve, unit must be removed and bladder replaced.

Ventilation and
Combustion Air System
Exhaust Assembly Weld &
Fastener Inspection
• Semi-Annually (Increase
frequency if excessive
wear is noted.)
GE
• Inspect per latest revision of TS00002199 Exhaust Assembly Weld & Fastener Inspection. Repair as necessary.

Ventilation and
Combustion Air System
Inlet Silencer • Annually GE
• Visually inspect per SPM-113 Ventilation and Combustion Air System Maintenance. • Ensure drains are clear.

Ventilation and
Combustion Air System
Filter Module -to-Silencer
Seals
• Annually GE
• Visually inspect for cracks and other signs of separation and failure.

Ventilation and
Combustion Air System
FOD Screen • Annually GE
• Inspect metal screen for damage, missing or loose hardware.

Ventilation and
Combustion Air System
FOD Sock • Annually GE
• Inspect nylon mesh screen for damage, tears, material integrity or decay. Replace if necessary.

Ventilation and
Combustion Air System Combustion Air Path, Turbine
Enclosure and Generator
Cooling Filter Pressure
Differential Transmitters
(PDTs)
• Annually GE • Visually inspect to ensure it is not damaged. • Ensure transmitter is free of moisture.
• Ensure electrical connections are not damaged.
• • Calibrate per manufacturer recommendation. Set zero and span to 4 and 20 mA at required pressures. Can be calibrated more often if drift occurs.
• If malfunction is suspected, verify that the hardware and process connections are in good working order. • If the unit is still malfunctioning, refer to the Rosemount manufacturer maintenance and troubleshooting manual for further instructions.

Ventilation and
Combustion Air System
Turbine Enclosure Ventilation
Fan Motor MOT-4017
• Monthly
• As required
O&M Contractor
• Grease in accordance with TP2010
Ventilation and
Combustion Air System
Temperature Sensors (RTDs) • Annually GE • Visually inspect the element. Ensure element is not damaged. • Function check with a calibrated meter if temperatures observed seem to be incorrect:
• Replace element and seals whenever variation in the controlled temperature is noticed. • Inspect and clean engine cable connectors with contact cleaner. • Tighten cable connectors.
• Replace on component failure.

Ventilation and
Combustion Air System
Air Conditioner MOT-4270 • Monthly O&M Contractor • Inspect to ensure temperature setting is correct as per site specific Flow and Instrumentation Diagram( F&ID). • Inspect for unwanted condensation.

Ventilation and
Combustion Air System
Battery Compartment
Ventilation Fan
• Weekly O&M Contractor
• Confirm fan is ventilating the compartment as required.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

Ventilation and
Combustion Air System
Generator Space Heaters
HE- 4050 and HE-4051
• Annually GE
• Inspect per generator manufacturer’s recommendations.

Ventilation and
Combustion Air System
Generator Cooling Filtration
Media
• Annually
• As required
GE • Change filtration media upon DP or annually.
• Inspect regularly for visual signs of deterioration or problems.

Ventilation and
Combustion Air System
Clean Air Filtration Media • Annually
• As required
GE • Inspect filtration media as described in SPM-113 and change on DP. • Inspect for damage Inspect regularly for visual signs of deterioration or problems.

Vibration System Vibration Proximity Probes • Annually GE • Visually inspect the element to ensure it is not damaged. • Check the gap voltage.
• In the instance of a problem, look for short between the signal common and the shield that could create ground loops and induce noise. • Ensure that the noise level remains in accordance with the specification by which it was designed. If the sensor does not perform within the specified limits, send to repair or replace element.

Vibration System Vibration Accelerometer
Probes
• Annually GE • Visually inspect the element to ensure it is not damaged • In the instance of a problem, look for short between the signal common and the shield that could create ground loops and induce noise. • Ensure that the noise level remains in accordance with the specification by which it designed. If the sensor does not perform within the specified limits, send to repair.

Vibration System Generator Speed Element
(SE8100)
• Annually GE • Visually inspect the element to ensure it is not damaged. • In the instance of a problem, look for short between the signal common and the shield that could create ground loops and induce noise. • Ensure that the noise level remains in accordance with the specification by which it designed. If the sensor does not perform within the specified limits, send to repair.

Water Wash System Tank • Annually GE • Inspect tank for leaks and damage, and to ensure vents are free from debris.

Water Wash System Valves • Annually GE • Ensure valve is not damaged and check for leaks at valve connections, tighten as necessary.

Water Wash System Tank Level Transmitter • Annually GE • Ensure transmitter is free from moisture and that the cover and connections are tight. • Calibrate per manufacturer recommendation.

Water Wash System

Filter
• Semi-Annually GE • Replace the in-line filter element with new seals every 6 months, or as necessary. • Ensure spring is not damaged.
• Replace filter when clogged.
• Ensure the in-line filter is not leaking after replacement.

Water Wash System Pump • Annually
GE • Check pump and motor for excessive vibration during operation. • Ensure electrical connections are not damaged.
• Ensure pump is not leaking or damaged.
• If abnormal conditions exist; motor should be removed and pump disassembled per manufacturer instructions.

Water Wash System Flow Meter • Annually GE • Ensure meter assembly is not damaged or leaking. • Ensure electrical connection at pickoff is not damaged. • Ensure the meter is flowing freely.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

TABLE 2: TM2500 PRESERVATION

Item

INSTALLED

ENGINE/POWER

TURBINE

NON INSTALLED

ENGINE/POWER

TURBINE NOT

STORED IN A

CONTAINER

NON INSTALLED

ENGINE/POWER

TURBINE STORED

IN A CONTAINER
Storage Period (days) <30 >30 <30 >30 <30 >30
Follow requirements of WP 002
00 X X X X X X
Inspection of Inlet and Exhaust X X X X
Add 5% BRAYCO to lubricating oil X X X
Water wash X X
Operate engine at idle speed to
wet bearings
X X
Oil wet bearings X X X X
Use a cover on inlet and exhaust X X
Put a cover or plug on all
engine openings and
unattached fittings

X X X X X X
Repeat oil wetting procedure
every 30 days
X X
Maintain oil wetting/storage log X X X
Applicable Paragraph B1-8 B1-9 B1-10 B1-11 B1-13 B1-12

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

EXHIBIT B
[RESERVED

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

EXHIBIT C

NOTICE AND COMMUNICATION PROTOCOLS

Notice to DWR

Delphine Hou
Deputy Director, Statewide Energy
California Department of Water Resources
715 P Street, 8th Floor
Sacramento, CA 95814
Email: [email protected]

Colin A. Wood
Office of General Counsel
California Department of Water Resources
715 P Street, 7th Floor
Sacramento, CA 95814
Email: [email protected]

Notice to Owner

City of Roseville
Attn: City Clerk
311 Vernon Street
Roseville, CA 95678

Roseville Electric
Attn: Electric Utility Director
116 S. Grant Street
Roseville, CA 95678

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

EXHIBIT D
Insurance

1. At all times during the Term of this Agreement, each Party shall maintain, at its own expense, with responsible insurers who maintain a financial strength rating of “A -” or higher and a financial size category of VIII or higher with AM Best, or through an applicable public agency insurance risk pool or other self-insurance, the insurance described below with coverages no less than the minimums indicated. If either Party fails to comply with the provisions of this Exhibit D, it shall hold harmless and indemnify the other Party from any direct or indirect losses and liability, including attorney’s fees and costs of litigation, resulting from the injury or death of any person or damage to any property, to the extent the indemnified Party would have been protec ted had the indemnifying Party complied with the requirements of this Exhibit D.

(a) General Liability. Each Party shall maintain general liability on an occurrence form with limits not less than one million dollars ($1,000,000) per occurrence for bodily injury and property damage liability and an annual policy aggregate of three million dollars ($3,000,000). The policy shall include coverage for liabilities arising out of premises, operations, independent contractors, products, completed operations, personal & advertising injury, and liability assumed under an insured contract. This insurance shall apply separately to each insured against whom claim is made or suit is brought subject to each Party’s limit of liability. The policy shall be endorsed to incl ude the other Party, its officers, agents, and employees as additional insureds, but only with respect to work performed under the Agreement and the indemnity obligations hereunder.

(b) Automobile Liability. Each Party shall maintain motor vehicle liability with limits not less than one million dollars ($1,000,000) combined single limit per accident. Such insurance shall cover liability arising out of a motor vehicle including owned, hired and non-owned motor vehicles. The policy shall be endorsed to include the other Party, its officers, agents, and employees as additional insureds, but only with respect to work performed under the Agreement and the indemnity obligations hereunder.

(c) Worker’s Compensation and Employer’s Liability. Each Party shall maintain statutory worker’s compensation and employer’s liability coverage for all its employees, or employees of its Affiliate, who will be engaged in the performance of the Agreement. Employer’s liability insurance shall not be less than one million dollars ($1,000,000) for injury or death occurring as a result of each accident.

(d) Excess/Umbrella Liability Insurance. Excess/umbrella liability insurance covering claims in excess of the unde rlying insurance described in Sections 1(a) through 1(c) with a combined single limit and annual aggregate limit of twenty -five million dollars ($25,000,000). The policy shall be endorsed to include the other Party, its officers, agents, and employees as additional insureds, but only with respect to work performed under the Agreement and the indemnity obligations hereunder.

(e) Pollution Liability. Each Party shall maintain pollution liability coverage with limits not less than five million dollars ($5,000 ,000) per incident and ten million dollars Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

($10,000,000) in the annual aggregate covering liability for bodily injury, property damage, and environmental damage resulting from pollution and related cleanup costs incurred, all arising under this Agreement. Coverage shall be provided for both work performed on the Site and during transportation as well as proper disposal of hazardous materials. Proof of Pollution Liability coverage during transportation can also be provided by endorsement to the Auto Liability policy.

(f) Professional Liability. As applicable, Roseville shall require any Contractor performing construction related services to maintain errors and omissions/ professional liability coverage with limits not less than five million dollars ($5,000,000) each occurrence and in the annual aggregate.

(g) Property Insurance. Roseville shall obtain and maintain in full force and effect during the term of this Agreement, all-risk property insurance in an amount equal to the full replacement cost value with respect to any equipment, parts, materials or other property , including but not limited to all property associated with the Project, owned by Roseville with sublimits as appropriate for facilities similar to this Site. Roseville shall be liable for all deductible amounts under any such all -risk property coverage. The policy shall waive all rights of subrogation against the other Party.

2. If any policy is written on a claims-made basis, provide the following:

(a) The Retroactive Date must be shown and must be before the date of the Agreement or the beginning of work performed under the Agreement.

(b) Insurance must be maintained and evidence of insurance must be provided for at least three (3) years after completion of the Agreement.

(c) If coverage is canceled or non -renewed, and not replaced with another claims - made policy form with a Retroactive Date prior to the Execution date, the Seller must purchase “extended reporting” coverage for a minimum of three (3) years after completion of the Agreement.

3. Coverage Term. Coverage shall remain in force for the complete term of the Agreement.

If insurance expires during the term of the Agreement, a new certificate must be provided to the other Party as soon as practicable but no later than 15 days following the expiration of the insurance.

4. Deductible. Each Party is responsible for any deductible or self -insured retention contained within their insurance program.

5. Primary Clause. Any required insurance contained in this Agreement shall be primary, and not excess or contributory, to any other insurance carried by the other Party.

6. Inadequate Insurance. Inadequate or lack of insurance does not negate Each Party’s obligations under the Agreement.

7. Should either party elect to self-insure for any required insurance, that Party shall be liable to O&M Contractor for the full equivalent of insurance coverage which would have been Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273

available to O&M Contractor the applicable insurance policies had been obtained by the Party from a third party insurer, in full compliance with the provisions under this Exhibit D, and shall pay on behalf of or indemnify O&M Contractor for all amounts which would have been payable by the third party insurer. In addition, CDWR shall act with the same promptness and be subject to the same standards of good faith as would apply to a third party insurance company.

8. Waiver of Subrogation. All insurance or self -insurance required by this Exhibit D shall waive any right of recovery the insurer (or CDWR in the case of self-insurance) may have against the other Party because of payments th e insurer or CDWR makes for injury or damage in connection with this Agreement.

9. Certificate(s). Certificate(s) shall include at least the following information: (i) the name of the insurance company, policy number and expiration date; (ii) the coverage and limits per required coverage, including the amounts of deductibles or self-insured retentions.

Docusign Envelope ID: 0A5B7FDA-66DE-485C-A0B0-0EB81E29F273 RESOLUTION NO. 25-083

APPROVING A SECOND AMENDED AND RESTATED OPERATIONS AND

MAINTENANCE AGREEMENT, BY AND BETWEEN THE CITY OF ROSEVILLE AND

THE CALIFORNIA DEPARTMENT OF WATER RESOURCES, AND AUTHORIZING THE

CITY MANAGER TO EXECUTE IT ON BEHALF OF THE CITY OF ROSEVILLE

WHEREAS, a Second Amended and Restated Operations and Maintenance Agreement relating to electric generation facilities at the Roseville Power Plant #2, by and between the City of Roseville and the California Department of Water Resources, has been reviewed by the City Council; and

NOW, THEREFORE, BE IT RESOLVED by the Council of the City of Roseville that said Second Amended and Restated Operations and Maintenance Agreement is hereby approved and the City Manager is authorized to execute it on behalf of the City of Roseville.

BE IT FURTHER RESOLVED that the City Manager of the City of Roseville is authorized to approve necessary adjustments to the exhibits for the Agreement, as approved by the City Attorney, to remain in operational compliance and/or for reporting purposes, as required.

PASSED AND ADOPTED by the Council of the City of Roseville this ___ day of ______________, 2025, by the following vote on roll call:

AYES COUNCILMEMBERS:

NOES COUNCILMEMBERS:

ABSENT COUNCILMEMBERS:

______________________________
MAYOR

ATTEST:

________________________
City Clerk

[3/21/2025]

DESIGN-BUILD CONSTRUCTION AGREEMENT
(PROJECT: ROSEVILLE POWER PLANT #2 REPOWER)

This Design-Build Construction Agreement ("Agreement") is made and entered into this ____ day of ______________, 20___, by and between the City of Roseville, a municipal corporation ("CITY") and Integrated Engineers & Contractors Corporation, a California corporation ("CONTRACTOR").

RECITALS

WHEREAS, CITY has issued a Request for Proposals pursuant to which CITY solicited proposals from design-build contractors to construct the ROSEVILLE POWER PLANT #2 REPOWER project ("Project"); and

WHEREAS, CONTRACTOR has submitted a Proposal, dated January 30, 2025 attached hereto and made a part hereof as Exhibit F, and CITY has selected CONTRACTOR to provide design and construction services as set forth in this Agreement; and

WHEREAS, CONTRACTOR is ready, willing and able to perform the aforementioned services required in accordance with the terms and conditions of this Agreement; and

NOW, THEREFORE, CITY and CONTRACTOR agree as follows:

ARTICLE 1

DEFINITIONS

1.1 "Applicable Laws" means all laws, codes, ordinances, rules and regulations of governmental authorities having jurisdiction over the Site and/or the Work.

1.2 "Application for Payment" means the document prepared by CONTRACTOR and submitted to CITY showing CONTRACTOR’s entitlement to progress payments, the requirements of which are more fully described in Section 5.3 hereof.

1.3 “Architect/Engineer” means a licensed professional(s) (and/or entity(ies)) retained by CONTRACTOR, with the approval of CITY, who provides architectural, design and/or engineering services as may be required by the Work. The Architect/Engineer shall be registered in the State of California and the architect and/or engineer of record for the Work pursuant to their design responsibilities. The Architect/Engineer shall be the Architect/Engineer(s) stated in the Proposal, unless substituted by CONTRACTOR based upon CITY’s written pre-approval.

1.4 "Authorized Representatives" means the Design-Build Team and those individuals appointed by CITY and CONTRACTOR from time to time in accordance with the provisions of Section 3.1.1.
2 [3/21/25]

1.5 "Business Day" means any day when the office of the City Clerk of the City of Roseville is open for business.

1.6 "Certificate of Substantial Completion" means a certificate prepared by CONTRACTOR in accordance with Section 5.12 and forwarded to CITY.

1.7 "Certificate of Final Completion" means a certificate prepared by CONTRACTOR and forwarded to CITY stating that the Project is finally complete and that CONTRACTOR is entitled to Final Payment in accordance with Article 5 hereof.

1.8 "Change Directive" means a written order signed by CITY directing a change in the Work. A Change Directive shall state a proposed basis for adjustment, if any, in the GMP or Schedule. CITY may order changes in the Work within the general scope of the Contract, and a Change Directive shall be used in the absence of total agreement on the terms of a Change Order.

1.9 "Change Order" means a written order signed by CONTRACTOR and CITY authorizing a change in the Work, which also may adjust the GMP and/or the Schedule, and which shall constitute a Modification. The GMP and/or Schedule may be changed only by Change Order.

1.10 "Change Proposal" means a proposal for a Change Order submitted by CONTRACTOR to CITY, either at the request of CITY, or at CONTRACTOR's own initiative.

1.11 "Construction Allowance Items" [reserved]

1.12 "Construction Documents" means the plans and specifications prepared by the Design- Build Team for the Project, approved by CITY, and incorporated into this Agreement by reference after such approval, to be used to construct the Project. The Construction Documents shall set forth in detail all items necessary to complete the construction of the Project in accordance with the Contract Documents (subject to their completion following commencement of the Construction Phase). All amendments and modifications to the Plans and Specifications must be approved by CITY prior to incorporation into this Agreement. CONTRACTOR’s attention is hereby directed to the confidentiality requirements of Section 2.2.

1.13 "Construction Notice to Proceed" means the notice given by CITY to CONTRACTOR stating that the Site is available to CONTRACTOR and directing CONTRACTOR to commence construction of the Project in accordance with Section 4.2.1.

1.14 "Construction Phase" means the period beginning with the issuance of the Construction Notice to Proceed and ending on the date of Final Completion of the Project.

1.15 "Construction Work" means that portion of the Work consisting of the provision of labor, materials, equipment and services in connection with the construction of the Project as set forth in the Contract Documents.

3 [3/21/25]

1.16 "Contingency Costs” means those items of Cost of the Work attributable to a contingency for which CITY is responsible and which are payable by CITY to CONTRACTOR pursuant to a Change Order as provided in Article 6.

1.17 "Contract Documents" means this 1) Agreement, 2) its Exhibits, and 3) the Construction Documents, all of which, together with this Agreement, form the entire integrated agreement between CITY and CONTRACTOR. In the event of a conflict between any of these documents, this Agreement controls, followed by its Exhibits.

1.18 "Contract" or “Agreement” means this Design-Build Construction Agreement, its exhibits, and all amendments and/or modifications hereto executed by the parties.

1.19 "Contract Time" means the period of time, including authorized adjustments, allotted in the Schedule for the Final Completion of the Work.

1.20 "CONTRACTOR" means the individual or entity identified in the preamble to this Agreement.

1.21 "CONTRACTOR Event of Default" shall have the meaning set forth in Section 12.1 hereof.

1.22 "Cost of the Work" consists of those items of Work, which are paid for by CITY to CONTRACTOR, and consist of those categories of costs set forth as allowable on Exhibit A.

1.23 "CPM" means a critical path method schedule in the form of precedents, networks and time sequences.

1.24 "Day" or "Days" means calendar days.

1.25 "Delay Costs” means those items of Cost of the Work attributable to an Excusable Delay for which CITY is responsible and which are payable by CITY to CONTRACTOR pursuant to a Change Order as provided in Article 6.

1.26 “Design-Build Team” includes the following: Architect/Engineer; CONTRACTOR; and/or others as coordinated by CONTRACTOR and CITY.

1.27 "Design Development Documents" means the drawings, specifications and other documents prepared by the Design-Build Team for CITY's review and approval prior to the preparation of the Construction Documents. The Design Development Documents shall illustrate the scale and relationship of Project components, outline the nature and structural exterior and three dimensional scale of the Project and shall fix and describe in detail the configuration and character of the Project concerning all items of the Project necessary for the complete and final preparation of the Construction Documents in accordance with the requirements of the Contract Documents, including architectural and electrical systems, materials and such other elements as may be appropriate. CONTRACTOR’s attention is hereby directed to the confidentiality requirements of Section 2.2.
4 [3/21/25]

1.28 "Design Materials" means any and all documents, shop drawings, electronic information, data, plans, drawings, sketches, illustrations, specifications, descriptions, models and other information developed, prepared, furnished, delivered or required to be delivered by CONTRACTOR to CITY under the Contract Documents or developed or prepared by CONTRACTOR specifically to discharge its duties under the Contract Documents.

CONTRACTOR’s attention is hereby directed to the confidentiality requirements of Section 2.2.

1.29 "Design Work" means that portion of the Work consisting of the design services required to be provided in connection with the design of the Project as set forth in the Contract Documents, which shall be performed consistent with the standards of professional care set forth herein.

1.30 "Excusable Delay" shall have the meaning set forth in Section 4.4.2 hereof.

1.31 "Fee", if applicable, means the fee payable to CONTRACTOR pursuant to this Contract and as part of the GMP, if shown on Exhibit A attached hereto.

1.32 "Final Completion" means the point at which the Work has been completed in accordance with the terms and conditions of the Contract Documents, including completion of all Punch list items.

1.33 "Force Majeure" means labor dispute (excluding labor shortage), fire, unusual delay in transportation or delivery, unavoidable casualty, flood (assuming CONTRACTOR has taken reasonable precautions), earthquake, epidemic, civil disturbance, war, freight embargo, riot, sabotage (by persons other than CONTRACTOR or Subcontractors), material shortage or any other similar act or condition, in each case only to the extent the event in question is beyond the reasonable control of and without the fault or negligence of CONTRACTOR.

1.34 "Governmental Approvals" means those CITY approvals necessary for the completion of the Project, including, but not limited to, modification of existing zoning, vacation of certain streets and/or alleys, and modifications to or variances from applicable building or zoning regulations.

1.35 "Guaranteed Maximum Price" or "GMP" means the amount set forth on Exhibit A hereto, which may be increased or decreased in accordance with the provisions of the Contract Documents.

1.36 "Hazardous Materials" means those items identified on Exhibit C hereto.

1.37 "Indemnified Parties" includes, but is not limited to, CITY, its agents, officers, employees, and volunteers.

1.38 "Liquidated Damages" means the damages payable by CONTRACTOR to CITY in the event CONTRACTOR does not achieve Final Completion of the Project by the date required on the Schedule, as adjusted, as more fully described in Section 4.6 hereof. 5 [3/21/25]

1.39 "Modification" means an amendment to this Agreement executed by the parties after the date hereof.

1.40 "Party" shall mean CITY or CONTRACTOR individually, and "Parties" shall mean CITY and CONTRACTOR collectively.

1.41 "Payment and Performance Bonds" means the payment bond and performance bond issued by an admitted Surety covering the faithful performance and completion of the Construction Work, including payment for all materials and labor furnished or supplied in connection with the Construction Work, by CONTRACTOR. Such bonds shall be in the form described in Exhibit E.

1.42 "Project" means the design and construction of the project described in the Recitals, together with all on-site infrastructure, site improvements and appurtenances to be designed, if any, constructed and installed in connection therewith, as more fully set forth and described in the Contract Documents and as required thereby or reasonably inferred therefrom.

1.43 "Project Manager" means the person assigned by the director of the CITY administering department to monitor the Project and Work.

1.44 "Punch List" means those minor items of Work to be completed after Substantial Completion and prior to Final Completion, which do not prevent the Project from being used for the purpose for which it is intended and which will not prevent beneficial occupancy or use.

1.45 "Retention" means the amount withheld from progress payments from CITY to CONTRACTOR from time to time, as more fully described in Article 5 hereof.

1.46 "Schedule" means the schedule pursuant to the Proposal and/or other Contract Documents to which CONTRACTOR has agreed to complete the Work. The Schedule shall be adjusted pursuant to the provisions of the Contract Documents. In the event the Schedule is not contained within the Proposal, then CONTRACTOR shall provide to CITY, within fifteen (15) days of issuance of a notice to proceed by CITY, with a complete milestone schedule identifying, among other things, critical paths (if any) and total calendar days until Substantial and Final Completion. In the event the Schedule is contained in the Proposal, the start of the Schedule shall be adjusted by the CONTRACTOR to reflect the date of the Notice To Proceed.

1.47 "Scheduled Date of Substantial Completion" means the date CONTRACTOR has agreed to achieve Substantial Completion of the Project in accordance with the Schedule, as adjusted.

1.48 "Scope Change Costs" means those items of Cost of the Work attributable to changes in scope of the Work and payable by CITY to CONTRACTOR pursuant to a Change Order, as provided in Article 6.

6 [3/21/25]

1.49 "Separate Contractors" means those individuals or entities (including, but not limited to, concessionaires) who have entered into arrangements with CITY for the provision of labor, materials or other services in connection with the Project.

1.50 "Site" is the real property on which the Project will be located.

1.51 "Subcontract" means an agreement between CONTRACTOR and another person or entity engaged to perform a portion of the Work.

1.52 "Subcontractor" means an individual or entity who has entered into an agreement with CONTRACTOR or another Subcontractor for the provision of labor, materials or other services required to be performed by CONTRACTOR under the Contract Documents.

1.53 "Substantial Completion" means the stage in the progress of the Work when the Work or a designated portion thereof is sufficiently complete in accordance with the Contract Documents so that CITY may use the Project for its intended purpose.

1.54 "Surety" means one or more issuers of the Payment and Performance Bonds, each of which shall be admitted and licensed to do business in the State of California.

1.55 "Unexcusable Delay" shall have the meaning set forth in Section 4.4.

1.56 "Work" or "Scope of Work" means the Project, inclusive of all labor, materials and services required to be performed or provided by CONTRACTOR officers, employees, agents, Subcontractors or Suppliers pursuant to the provisions of this Agreement and its Exhibits (including, the entirety of Exhibit F).

ARTICLE 2

SCOPE OF WORK / PROJECT REQUIREMENTS

2.1 Performance of Work. CONTRACTOR shall perform the Work in accordance with this Agreement. CONTRACTOR covenants and agrees that it shall be responsible for performing and completing, and for causing all Subcontractors (including Architect/Engineer) to perform and complete, the Work in accordance with the Contract Documents, standard professional and trade practices, and Applicable Laws. CONTRACTOR will retain an Architect/Engineer for design services required by the Work and the Architect/Engineer shall be the engineer of record. CONTRACTOR covenants that the Work and the materials provided thereunder shall be appropriate for the purposes stated in the Request for Proposal and Proposal.

Although it is the responsibility of CONTRACTOR to conform the Work to Applicable Laws at all times, to the extent there is a change in one or more Applicable Laws after the date of execution of this Contract, and such change has the effect of increasing the cost or time of performance of the Work, such change may be the subject of a Change Order under the provisions of Article 6 hereof.

7 [3/21/25]

2.1.1. Noise and Night Work. CONTRACTOR shall comply with PLACER COUNTY AND CITY’s noise ordinances.

2.2 Professional Standard; Ownership of Documents.

2.2.1 Standards of Performance. The Work shall be performed by CONTRACTOR in accordance with the professional standards applicable to projects, buildings or work of complexity, quality and scope comparable to the Work and the Project. CONTRACTOR may make such additions or substitutions to personnel and responsibilities as it deems necessary or appropriate in order to carry out its responsibilities hereunder, provided such personnel shall be suitably qualified. Nothing in this Agreement shall be construed to create any contractual liability with CITY toward any Subcontractor.

2.2.2 Design Documents and Materials, and Confidentiality.

2.2.2.1 CITY shall have unlimited rights to copy and use in connection with the Project all Design Materials, including the right to use same on the Project at no additional cost to CITY, regardless of degree of completion, provided that said services performed have been fully paid for as required by the terms of this Agreement. CONTRACTOR and its Sub- contractors shall keep all design documents confidential, and shall not disclose such documents except as may be required in performance of the Work or pursuant to legal process.

2.3 Local Conditions; Environmental Site Conditions.

2.3.1 Local Conditions. CONTRACTOR represents that it has taken steps reasonably necessary to ascertain the nature and location of the Work, and that it has investigated and satisfied itself as to the general and local conditions which are applicable to the Work such as (a) conditions bearing on transportation, disposal, handling and storage of materials; (b) the availability of labor, water, power and roads; (c) normal weather conditions; (d) observable physical conditions at the Site; (e) the surface conditions of the ground; and (f) the character of equipment and facilities needed prior to and during the performance of the Work. To the extent CONTRACTOR encounters subsurface or concealed conditions which differ materially from that actually known by CONTRACTOR on the date of this Agreement or from those ordinarily found to exist and generally recognized as inherent in the activities of the character provided in the Contract Documents; then CONTRACTOR shall give notice to CITY promptly before conditions are disturbed and in no event later than two (2) Days after the first observance of the conditions if a Change Order is contemplated by CONTRACTOR due to such condition. Such materially different conditions may entitle CONTRACTOR to an equitable adjustment in the GMP and/or Schedule pursuant to the Change Order provisions of this Agreement.

2.3.2 Hazardous Materials. The Parties' agreement as to the handling of Hazardous Materials discovered at the Site (and not brought there by CONTRACTOR or any Subcontractor) is set forth in Exhibit C hereto, and the only duties and responsibilities of CONTRACTOR in connection therewith are as therein specified, notwithstanding any other provision of this Agreement.

8 [3/21/25]

2.4 Design Development Documents and Construction Documents.

2.4.1 General. The Design-Build Team understands that all construction documents, working drawings and specifications (“Submittals”) must be coordinated with, and approved by, CITY prior to construction. CONTRACTOR shall allow CITY a minimum of fourteen (14) days for review of Submittals and corrections made thereto. CONTRACTOR shall work with the Design-Build Team to prepare, for the approval of CITY, working drawings and specifications setting forth in detail the requirements for the construction of the Project in its entirety including the necessary bidding information. CITY’s review of the Design Development Documents and the Construction Documents shall not relieve CONTRACTOR from its responsibilities under this Agreement, or be deemed to be an approval or waiver by CITY of any deviation from, or of CONTRACTOR's failure to comply with, any provision or requirement of the Contract Documents, unless such deviation or failure has been identified as such in writing in the document submitted for approval by CONTRACTOR and approved by CITY. CONTRACTOR shall comply with all CITY construction standards as deemed applicable by the CITY.

CONTRACTOR shall provide CITY with a complete, accurate, full size, and current set of as- built drawings in a hard copy acceptable to City prior to Final Completion.

2.4.2 Reliance on Approvals. CONTRACTOR shall be entitled to rely on the approvals of CITY with respect to the Design Materials. If CITY revokes, modifies or otherwise changes in a material way its approval of a given system after such system has been designed and approved, or modifies the original Scope of Work in a material manner requiring modification to one or more systems which have been designed and approved, CONTRACTOR shall be entitled to a Change Order in accordance with the provisions of Article 6 hereof, provided that prior to such approval CONTRACTOR has made CITY aware of future design decisions which may be affected by such approval. No Change Order shall be issued to the extent such modification is due to the fault or neglect of CONTRACTOR.

2.4.3 Review of Contract Documents and Field Conditions. CONTRACTOR shall take field measurements and verify field conditions and shall carefully compare such field conditions and other information known to CONTRACTOR with the Contract Documents before commencing activities. CONTRACTOR shall perform the Work in accordance with the Contract Documents and submittals approved in accordance with the procedures set forth in this Agreement.

2.5 Legal Requirements. CONTRACTOR shall comply with Applicable Laws, and shall give applicable notices pertaining thereto. Except with respect to Governmental Approvals, CONTRACTOR shall prepare and file all documents required to obtain the necessary approvals of governmental authorities having jurisdiction over the Work and/or the Project and shall secure and pay for permits and governmental fees, licenses and inspections necessary for the proper execution of the Work and completion of the Project. Notwithstanding the foregoing, CITY has informed CONTRACTOR that fees in connection with building permits, street use permits, and similar permits relating to construction will be waived and are not to be included in the GMP. If and to the extent charges in the future for such permits are imposed in the future, such charges shall be paid by CITY, or shall be the subject of a Change Order to the Contract in accordance with the Change Order provisions of this Agreement.
9 [3/21/25]

2.6 Services and Facilities.

2.6.1 General. CONTRACTOR shall provide everything required for the orderly progress and proper execution and completion of the Work and the Project in accordance with the requirements of the Contract Documents, whether temporary or permanent and whether or not incorporated or to be incorporated into the Work, including, but not limited to, services, labor, materials, equipment, furnishings, tools, construction equipment and machinery, utilities, transportation and other facilities and services.

2.6.2 Supervision. CONTRACTOR shall supervise and direct the Work in accordance with its best skill and attention. CONTRACTOR shall be solely responsible for and have control over construction means, methods, techniques, sequences and procedures. CONTRACTOR shall be responsible to CITY for the acts and omissions of, and whenever this Contract refers to the negligence, fault or omission of CONTRACTOR, such term shall include the negligence, fault or omission of, CONTRACTOR's employees, Subcontractors and their agents and employees, and other persons performing portions of the Work under an agreement with CONTRACTOR.

CONTRACTOR shall not be relieved of obligations to perform the Work in accordance with the Contract Documents by tests, inspections or approvals required or performed by persons other than CONTRACTOR.

2.6.3 Coordination. CONTRACTOR shall coordinate construction requirements with governmental agencies, utilities, and all other parties either involved in infrastructure improvements or otherwise affected by the design and construction requirements.

2.6.3.1 Design-Build Development Coordination. CONTRACTOR understands and agrees that all Design Development Documents and time schedules prepared by Architect/Engineer must be coordinated with CONTRACTOR and CITY. CONTRACTOR shall participate and provide recommendations in the development of the drawings and other documents to fix and describe the size and character of the Project in its entirety as to structural, and electrical systems, materials and other essentials as may be necessary according to good engineering and architectural practice.

2.6.3.2 Construction Documents Coordination. [reserved]

2.6.4. Cooperation. CONTRACTOR shall cooperate with the Architect/Engineer, and CITY’s financial, design and construction consultants and all other designated representatives during the design and construction of the Project.

2.6.5 Management. CONTRACTOR shall implement suitable management systems and work plans for the Project relative to Project safety, quality assurance and managing and controlling the Work.

2.6.6 Reports. CONTRACTOR shall prepare and submit to CITY monthly progress reports on the Work accomplished during the previous monthly period, which reports shall be prepared in a manner and in a format reasonably acceptable to CITY. Such reports shall be 10 [3/21/25]

furnished at the time of submission of each monthly Application for Payment. As part of such report, CONTRACTOR shall provide an updated Schedule, including CPM, if any, illustrating the progress that has been made, by reference to the initial CPM, and specifying whether the Work is on schedule or behind schedule and actions being taken to correct Schedule slippage.

The monthly report shall also set forth CONTRACTOR's projected progress for the forthcoming month.

2.7 Warranty. CONTRACTOR warrants to CITY that any and all materials, equipment and furnishings incorporated in the Work will be of good quality and new unless otherwise required or permitted by the Contract Documents, that the Work will be free from defects not inherent in the quality required or permitted, and that the Work will conform with the requirements of the Contract Documents. Work not conforming to these requirements, including substitutions not properly approved and authorized, may be considered defective by CITY at its sole discretion.

CONTRACTOR shall warranty the Work for materials and workmanship for a period of two-years commencing upon recording of the notice of completion. If within this two-year warranty period any of the Work is found to be defective or not in accordance with the requirements of the Contract Documents, CONTRACTOR shall correct it promptly after receipt of written notice from CITY to do so. CITY shall give such notice promptly after discovery of the condition. CONTRACTOR shall bear the cost of correction. All equipment warrantees will be consistent with the manufacturer’s standard warranties.

CONTRACTOR’s attention is directed to Section 9.3 below regarding Warranty Bond requirements.

2.8 Taxes. CONTRACTOR shall pay, as Cost of the Work, all existing and future applicable federal, state and local sales, consumer, use and similar taxes, whether direct or indirect, relating to, or incurred in connection with, the performance of the Work (excluding taxes based on CONTRACTOR's income). In the event CONTRACTOR is obligated to pay any new or increased taxes or duties adopted after the date hereof, the amount of such new or increased taxes shall increase the GMP pursuant to the Change Order provisions of this Contract. In the event CONTRACTOR receives the benefit of a tax exemption or tax reduction taking effect after the date hereof, the amount of such exemption or reduction shall decrease the GMP pursuant to the Change Order provisions of this Contract

2.9 Access by CITY. CONTRACTOR shall afford CITY and its authorized designees access to the Project Site at all times, subject to reasonable prior notice for access outside of normal business hours.

2.10 Use of Site. CITY shall be permitted beneficial use of the Work.

2.11 Patents, Trademarks, Copyrights. CONTRACTOR shall pay, as a Cost of the Work, all-applicable royalties and license fees on any matters arising in connection with the Work.

CONTRACTOR shall defend all suits or claims for infringement of patent, trademark, and copyrights against the Indemnified Parties, and shall save the Indemnified Parties harmless from loss on account thereof for any and all matters arising in connection with the Work or the Project 11 [3/21/25]

(such costs to be paid as Cost of the Work), except with respect to any particular design process or the product of a particular manufacturer or manufacturers specified and required by CITY, other than pursuant to the recommendation or suggestion of CONTRACTOR or a subcontractor; provided however, if CONTRACTOR has reason to believe that the design, process or product so specified is an infringement of a patent, CONTRACTOR shall be responsible for any loss resulting unless CONTRACTOR has provided CITY with prompt written notice of CONTRACTOR's belief, and CITY has nevertheless elected to go forward with such design, process or product so specified.

2.12 Rubbish; Debris; Cleanup. During the performance of all on-site Work, CONTRACTOR shall at all times, as a Cost of the Work, keep the Site and adjacent streets, properties and sidewalks reasonably free from waste materials, debris and/or rubbish, and shall employ adequate dust control measures. If accumulation of such materials, debris, rubbish or dust constitutes a nuisance or safety hazard or is otherwise objectionable in the reasonable opinion of CITY, CONTRACTOR shall promptly remove them. Upon Substantial Completion of the Work, or any portion or component thereof, CONTRACTOR shall remove from the Site, or applicable portion thereof, all tools, construction equipment, machinery, surplus materials, waste materials and rubbish and shall leave the Site in a "broom clean" condition. If CONTRACTOR fails to clean up as provided in the Contract Documents, CITY may do so and the cost thereof shall be charged to CONTRACTOR as a Cost of the Work.

2.13 Permits, Fees and Notices. Unless otherwise provided in the Contract Documents, and subject to the provisions of Section 2.5 hereof, CONTRACTOR shall secure all permits, governmental fees, licenses and inspections necessary for the proper execution and completion of the Work. To the extent there is a change in the type or cost of any of such permits, fees, licenses or inspection occurring after execution of this Agreement, there shall be an equitable adjustment in the GMP and Schedule on account of such change in accordance with the Change Order provisions. CONTRACTOR shall comply with and give notices required by Applicable Laws. CITY shall be responsible for obtaining California Energy Commission (CEC) and Air Board permitting.

2.14 Shop Drawings, Product Data, Samples and Other Submittals.

2.14.1 Documents and Samples at the Site. From and after commencement of the Construction Work, CONTRACTOR shall maintain at the site one record copy of the Construction Documents, and any and all amendments thereto, in good order and marked to record changes and selections made during the Construction Phase. In addition, CONTRACTOR shall maintain at the site approved shop drawings, product data, samples and similar required submittals. These shall be provided to CITY upon completion of the Work.

2.14.2 Shop Drawings, Product Data, Samples and Other Submittals.

2.14.2.1 Shop Drawings are drawings, diagrams, schedules and other data specially prepared for the Work by CONTRACTOR, a Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.

12 [3/21/25]

2.14.2.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by CONTRACTOR to illustrate materials or equipment for some portion of the Work.

2.14.2.3 Samples are physical examples, which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged.

2.14.2.4 Shop Drawings, Product Data, Samples and similar submittals are not Contract Documents. The purpose of their submittal is to demonstrate for those portions of the Work for which submittals are required the way CONTRACTOR proposes to conform the construction to the Construction Documents.

2.14.2.5 Submission of items listed in section 2.14.2.4. [reserved]

2.14.3 Responsibility. CONTRACTOR shall not be relieved of responsibility for the deviations from requirements of the Contract Documents by CITY's approval of Shop Drawings, Product Data, Samples or similar submittals unless CONTRACTOR has specifically informed CITY of such deviation at the time of the submittal and CITY has given written approval to the specific deviation. CONTRACTOR shall not be relieved of responsibility for errors or omissions in Shop Drawings, Product Data, Samples or similar submittals by CITY's approval thereof.

2.15 Tests and Inspections

2.15.1 Initial Tests and Inspections. Tests, inspections and approvals of portions of the Construction Work shall be made as required by the Contract Documents, Applicable Laws or normal construction practices and/or as directed by CITY. Unless otherwise provided, CONTRACTOR shall make arrangements for such tests, inspections and approvals with an independent testing laboratory or entity acceptable to CITY, or with the appropriate public authority. The costs of such tests, inspections and approvals shall be a cost paid by CONTRACTOR. CONTRACTOR shall give CITY timely notice of when and where tests and inspections are to be made so that CITY may observe such procedures. All costs of tests, inspections or approvals imposed upon CONTRACTOR by changes in Applicable Laws occurring after execution of this Agreement shall be an increase to the GMP in accordance with the Change Order provisions herein.

2.15.2 Additional Tests and Inspections. If CITY, or any other public authority having jurisdiction, determines that portions of the Construction Work require additional testing, inspection or approval beyond that required by subsection 2.15.1, CITY will instruct CONTRACTOR to make arrangements for such additional testing, inspection or approval by an entity acceptable to CITY, and CONTRACTOR shall give timely notice to CITY of when and where tests and inspections are to be made so CITY may observe such procedures. If such additional tests and/or inspections reveal failure of the portions of the Work to comply with the requirements of the Contract Documents, the costs of such tests and required correction shall be paid as a Cost of the Work, subject to the limitations set forth in Section 2.22 hereof. If the additional tests and/or inspections show that the portions of the Work comply with the 13 [3/21/25]

requirements of the Contract Documents, the costs thereof shall be an increase to the GMP in accordance with the Change Order provisions of this Agreement.

2.15.3 Required Certificates. Required certificates of testing, inspection or approval shall, unless otherwise required by the Contract Documents, be secured by CONTRACTOR and promptly delivered to CITY.

2.1 5.4 Timing of Testing. Tests or inspections conducted pursuant to the Contract Documents shall be made promptly to avoid unreasonable delay in the Work.

2.16 Execution, Correlation and Intent.

2.16.1 Execution of Agreement. Execution of this Agreement by CONTRACTOR is a representation that CONTRACTOR has visited the Site, become familiar with the local conditions under which the Work is to be performed and correlated personal observations with requirements of the Contract Documents.

2.16.2 Intent of Contract Documents. The intent of the Contract Documents is to include all items necessary for the proper execution and completion of the Work by CONTRACTOR. The Contract Documents are complementary and what is required by one shall be as binding as if required by all; performance by CONTRACTOR shall be required only to the extent consistent with the Contract Documents and reasonably inferable from them as being necessary to produce the intended results.

2.16.3 Organization of Materials. Organization of the Design Materials into divisions, sections and articles, and arrangement of drawings does not necessarily control CONTRACTOR in dividing the Construction Work among Subcontractors or in establishing the extent of Construction Work performed by any trade.

2.16.4 Meaning of Words. Unless otherwise stated in this Agreement, words which have well-known technical or construction industry meanings are used in accordance with such recognized meanings.

2.17 Labor and Materials; Liens (Stop Payment Notice Claims); Indemnity. Unless otherwise provided in the Contract Documents, CONTRACTOR shall provide and pay for labor, materials, equipment, tools, construction equipment and machinery, water, heat, utilities, transportation, and other facilities and services necessary for the proper execution and completion of the Work, whether temporary or permanent and whether or not incorporated or to be incorporated in the Work. CONTRACTOR shall enforce strict discipline and good order among CONTRACTOR's employees, subcontractors, and other persons carrying out the Work.

CONTRACTOR shall not permit employment of unfit persons or persons not skilled in tasks assigned to them.

CONTRACTOR shall not permit any Subcontractor, materialman, or laborer to place liens on the Project covering any portion of the Work for which CITY has made payment to CONTRACTOR. If any liens (e.g., stop payment notice claims) are imposed, CITY may 14 [3/21/25]

withhold payment in the amount of 125% of the claim until such time an unconditional release is provided in a form satisfactory to CITY. CONTRACTOR shall indemnify, defend, and hold harmless CITY regarding any claim or lien that proceeds to, or is the subject of litigation. CITY may withhold payment(s) pending compliance with this provision.

2.18 Cutting and Patching.

2.18.1 Cutting and Patching of the Work. CONTRACTOR shall be responsible for cutting, fitting, or patching required to complete the Work or to make its parts fit together properly.

2.18.2 Damage to Work of CITY or Separate Contractors. CONTRACTOR shall not damage or endanger a portion of the completed Work, fully or partially completed construction of CITY, or work or construction by Separate Contractor(s) by cutting, patching or otherwise altering such construction or work, or by excavation. CONTRACTOR shall not cut or otherwise alter such construction by CITY or a Separate Contractor except with written consent of CITY and of such Separate Contractor, such consent not to be unreasonably withheld.

2.19 Uncovering of Construction Work.

2.19.1 Uncovering. If a portion of the Construction Work is covered contrary to CITY's written request to observe such work prior to it being covered or contrary to requirements of the Contract Documents, it must, if directed in writing by CITY, be uncovered for CITY's observation and be replaced without change in the Schedule or GMP. The costs of such uncovering and replacement shall be Cost of the Work, subject to the limitation set forth in Section 2.22 hereof.

2.19.2 Covering of Work Requested to be Observed. If a portion of the Construction Work has been covered which CITY has not specifically requested to observe prior to it’s being covered, CITY may request to see such Construction Work and it shall be uncovered by CONTRACTOR. If such Construction Work is in accordance with the Contract Documents, costs of uncovering and replacement shall, by appropriate Change Order, be charged to CITY and shall increase the GMP. An appropriate time extension shall also be given. If such Construction Work is not in accordance with the Contract Documents, CONTRACTOR shall pay such costs as Cost of the Work, unless such condition was caused by CITY or a Separate Contractor in which event CITY shall be responsible for payment of such costs by appropriate Change Order, and an appropriate time extension shall also be given.

2.20 Correction of Work.

2.20.1 Work Rejected by CITY. CONTRACTOR shall promptly correct Construction Work rejected by CITY or failing to conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed. CONTRACTOR shall bear the costs of correcting such rejected Construction Work, as a Cost of the Work, including additional testing and inspection and compensation for services and expenses of CITY made necessary thereby.
15 [3/21/25]

2.20.2 [Intentionally deleted].

2.20.3 Removal of Work. CONTRACTOR shall remove from the Site portions of the Construction Work, which are not in accordance with the requirements of the Contract Documents and are neither corrected by CONTRACTOR nor accepted by CITY. The costs incurred in removing such Work shall be a Cost of the Work, subject to the limitation set forth in Section 2.22 hereof.

2.20.4 Failure to Correct Nonconforming Work. If CONTRACTOR fails to correct nonconforming Construction Work within a reasonable time, CITY may correct it in accordance with the terms of this Agreement. If CONTRACTOR does not proceed with correction of such nonconforming Construction Work within a reasonable time fixed by written notice from CITY, CITY may remove it and store the salvageable materials or equipment at CONTRACTOR’s expense. If CONTRACTOR does not pay costs of such removal and storage within ten (10) Days after written notice, CITY may, upon ten (10) additional Days written notice, sell such materials and equipment at auction or at private sale and shall account for the proceeds thereof, after deducting costs and damages that should have been borne by CONTRACTOR, including compensation for services and expenses made necessary thereby. If such proceeds of sale do not cover costs which CONTRACTOR should have borne, CONTRACTOR shall pay such excess to CITY. If such proceeds are in excess of the costs which CONTRACTOR should have borne, such excess shall be paid by CITY to CONTRACTOR. If such costs arise during the performance of the Work, such costs shall be charged against the Cost of the Work. If such costs arise after Substantial Completion, such costs shall be payable as provided in Section 5.1.

2.20.5 Damaged or Destroyed Work. CONTRACTOR shall bear the cost of correcting destroyed or damaged construction, whether completed or partially completed, of CITY or Separate Contractors caused by CONTRACTOR's correction or removal of Construction Work which is not in accordance with the requirements of the Contract Documents. If such costs arise during the performance of the Work, such costs shall be charged against the Cost of the Work. If such costs arise after Substantial Completion, such costs shall be payable as provided in Section

5.1. 2.20.6 No Limitation. Nothing contained in this section 2.20 shall be construed to establish a period of limitation with respect to other obligations which CONTRACTOR might have under the Contract Documents.

2.21 Value Engineering. CONTRACTOR shall suggest to CITY value engineering to reduce the cost of the Project, which CITY may accept at its sole discretion.

2.21.1 Subcontractors Bids. CONTRACTOR shall use its best effort to choose the highest quality of materials, equipment, component systems and types of construction for the most reasonable prices for inclusion in the Construction Documents, and make reasonable adjustments in the scope of the Project so that the total cost bid by the bidding Subcontractors will not exceed the estimate.

16 [3/21/25]

2.22 Acceptance of Nonconforming Work. If CITY prefers to accept Work, which is not in accordance with the requirements of the Contract Documents, CITY may do so instead of requiring its removal and correction, in which case the GMP will be reduced as appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made.

2.23 Contractor Registration. No contractor or subcontractor may work on a public works project unless registered with the Department of Industrial Relations pursuant to Labor Code section 1725.5. During the performance of this Contract, CONTRACTOR and its subcontractors shall have a continuing legal obligation to maintain current registration with the Department of Industrial Relations. CONTRACTOR is hereby notified that this Project is subject to compliance monitoring and enforcement by the Department of Industrial Relations.

ARTICLE 3

CITY'S RIGHTS AND RESPONSIBILITIES

3.1. Information and Services Required of CITY.

3.1.1 CITY Designation of Authorized Representative. Both Parties shall designate, from time to time, one or more representatives authorized to act on their behalf with respect to the Project, together with the scope of his/her respective authority. CONTRACTOR shall not be entitled to rely on directions from anyone outside the scope of that person’s authority as set forth in written delegations pursuant to this Agreement. Directions and decisions made by Authorized Representative(s) of CITY shall be subject to any further approval(s) required by any provisions of CITY’s Charter or the Roseville Municipal Code.

3.1.2 Communication. During the term of this Contract, CITY shall communicate with Subcontractors, suppliers and others performing any part of the Work only through CONTRACTOR's Authorized Representative.

3.1.3 Governmental Approvals. CITY shall be responsible for obtaining the Governmental Approvals. Any delay in obtaining the Governmental Approvals may entitle CONTRACTOR to an equitable adjustment in the Schedule and GMP in accordance with the Change Order provisions of this Agreement, except to the extent such delay is due to the fault or neglect of CONTRACTOR.

3.2 [Intentionally deleted.]

3.3 [Intentionally deleted.]

3.4 Activities on the Site by CITY or Separate Contractors.

3.4.1 CITY's Right to Award Separate Contracts. CITY reserves the right to perform work or operations related to the Project, with CITY's own forces, and to award separate contracts to Separate Contractors in connection with other portions of the Project.

17 [3/21/25]

3.4.2 Integration of the Work with Separate Contractors. Following the request of CITY, CONTRACTOR shall prepare a plan in order to integrate the work performed by Separate Contractors with the performance of the Work, and shall submit such plan to CITY for approval.

The plan shall be fair and reasonable for CONTRACTOR and the Separate Contractors, and CONTRACTOR shall work with the Separate Contractors to reach agreement on such plan.

CONTRACTOR shall arrange the performance of the Work so that the Work and the work of the Separate Contractors are, to the extent applicable, properly integrated, jointed in an acceptable manner, and performed in the proper sequence so that any disruption or damage to the Work or to any work of Separate Contractors is avoided.

3.4.3 Coordination. CONTRACTOR shall provide for the coordination of the activities of CONTRACTOR and its Subcontractors with the activities of the Separate Contractors. CONTRACTOR shall participate with all Separate Contractors and CITY in reviewing and coordinating the schedules of the Separate Contractors with the Schedule.

CONTRACTOR shall make any revisions to the Schedule deemed necessary to properly incorporate the work of the Separate Contractors with the Work. To the extent (a) the date of Substantial Completion is extended by such Schedule revision; (b) CONTRACTOR is required to perform its Work materially out of sequence, and in a manner which is not as efficient or cost effective as originally planned; or (c) the Scope of Work is increased, an equitable adjustment in the GMP and the Schedule shall be made in accordance with the Change Order provisions of this Agreement.

3.4.4 Use of Site. CONTRACTOR shall afford CITY and all Separate Contractors reasonable opportunity for storage of materials and equipment and performance of their work.

CONTRACTOR shall also connect and coordinate its Work and operations with CITY and all Separate Contractors' operations as required by the Contract Documents. CITY shall direct the Separate Contractors to cooperate with CONTRACTOR and to avoid actions or omissions, which could interfere with or delay the activities of CONTRACTOR.

3.4.5 Deficiency in Work of Contractors. If part of CONTRACTOR's Work depends upon proper execution or results upon construction or operations by CITY or a Separate Contractor, CONTRACTOR shall, prior to proceeding with that portion of the Work, promptly report to the Separate Contractor and CITY apparent discrepancies or defects in such other construction that would render it unsuitable for proper execution and results by CONTRACTOR.

CONTRACTOR and the Separate Contractor shall use good faith efforts to resolve any such discrepancies or defects or any disagreements relating thereto. Failure of CONTRACTOR to report such discrepancies or defects shall constitute acceptance by CONTRACTOR of the work of Separate Contractors as fit and proper to receive CONTRACTOR's Work (except as to those defects or discrepancies that are not apparent).

3.4.6 Claims Involving Separate Contractors. In the event that CONTRACTOR unnecessarily and unreasonably delays the work of Separate Contractors by not cooperating with them as required hereby, or by not affording them reasonable opportunity to perform their work as stated herein, CONTRACTOR shall, in such event, pay, as Cost of the Work, all reasonable direct incremental costs and expenses incurred by such Separate Contractors due to any such delays. If any Separate Contractor shall assert a claim or bring an action against CITY alleging 18 [3/21/25]

damage due to the fault or neglect of CONTRACTOR, CITY shall immediately notify CONTRACTOR, who shall defend such claim. If it is determined that CONTRACTOR was at fault, CONTRACTOR shall pay all costs of defense, including attorney's fees, as well as any resulting judgment or settlement, as a Cost of the Work.

3.5 Assignment of Separate Contracts. If CITY determines that it wishes to assign to CONTRACTOR one or more contracts between CITY and a Separate Contractor, it shall give CONTRACTOR written notice of such desire, including in such notice a copy of such contract for CONTRACTOR's review and approval. The Separate Contractor shall be fully qualified to perform the work under the to-be-assigned contract, shall possess the financial capability to perform its obligations under such to-be-assigned contract, and shall provide one hundred percent (100%) payment and performance bonds covering such work from sureties meeting the standards set forth in Section 1.53 hereof. Such contract shall contain provisions similar to those contained in CONTRACTOR's agreements with its Subcontractors with respect to liability, indemnification, retention, payment, labor, warranty, and other material items. Upon CONTRACTOR's approval of the assignment of such contract, which approval shall not be unreasonably withheld, delayed or conditioned, such Separate Contractor shall cease to be a Separate Contractor and shall thereafter be deemed to be a Subcontractor of CONTRACTOR, and the GMP shall be increased by Change Order in the amount of (a) such assigned contract, and (b) the additional Fee pursuant to the provisions of Section 6.5.1.

3.6 CITY's Right to Stop the Work. If CONTRACTOR persistently fails to correct Work which is not in accordance with the requirements of the Contract Documents and this Agreement or persistently fails to carry out the Work in accordance with the Contract Documents, CITY, by written order signed by CITY, may deliver a notice to CONTRACTOR setting forth that such a persistent and material failure is occurring and has occurred, and demanding that CONTRACTOR commence a cure of such persistent and material failure within twenty (20) Days and diligently pursue such cure thereafter. In the event that the cure is not commenced and pursued diligently, CITY may, by written notice to CONTRACTOR, order CONTRACTOR to stop the Work, or any portion thereof, until the use for such order has been eliminated; provided, however, that the right of CITY to stop the Work shall not give rise to a duty on the part of CITY to exercise this right for the benefit of CONTRACTOR or any other person or entity and shall not give rise to any liability of CITY to CONTRACTOR resulting from any delay (except to the extent that such order is found to be improper).

3.7 CITY's Right to Carry out the Work. If CONTRACTOR defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a seven (7) Day period after receipt of written notice from CITY to commence and diligently continue correction of such default or neglect with diligence and promptness, CITY may after such seven (7) Day period give CONTRACTOR a second written notice to correct such deficiencies within such second seven (7) Day period. If CONTRACTOR within such second seven (7) Day period after receipt of such second notice fails to commence and diligently continue to correct any deficiencies, CITY, without prejudice to other remedies CITY may have, may correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due to CONTRACTOR the cost of correcting such deficiencies, including Compensation for additional services and expenses made necessary by such default, neglect or 19 [3/21/25]

failure. If payments then or thereafter due to CONTRACTOR are insufficient to cover such amounts, CONTRACTOR shall pay the difference to CITY.

ARTICLE 4
TIME

4.1. Progress and Completion. Time limits stated in the Contract Documents are of the essence of this Agreement. By executing this Agreement, CONTRACTOR confirms that the Contract Time is a reasonable period of time for achieving Final Completion of the Work.

4.2 Schedule Obligations.

4.2.1 Contract Schedule and Notice To Proceed. CONTRACTOR shall provide a schedule as stated in Section 1.46. CONTRACTOR shall begin work pursuant to this Agreement and in accordance with the Schedule (as described in Exhibit F) within fifteen (15) calendar Days of the date of issuance of a Notice To Proceed by CITY, unless extended at the request made to and at the sole discretion of City. CONTRACTOR shall update said schedule to commence from the date of this Agreement, and the overall timeline shall remain consistent with the original schedule. CITY may issue the Notice To Proceed within fifteen (15) Days of full execution of this Agreement.

4.2.2 Prosecution of the Work. CONTRACTOR shall prosecute the Work so that the portion of the Work completed at any point in time shall be not less than as required by the Schedule. If the rate of progress is such that the total amount of Work and/or the degree of completion of the Project accomplished by CONTRACTOR within any time period required by the Schedule is less than the amount therein specified, CONTRACTOR shall so notify CITY. If the delay is an Unexcused Delay, CONTRACTOR shall prepare a recovery schedule for CITY's review and approval, showing how CONTRACTOR will compensate for the delays and achieve Final Completion by the date shown on the Schedule. If CONTRACTOR is unable to demonstrate how it will overcome Unexcused Delays, CONTRACTOR shall employ such extraordinary measures as are necessary to bring the Work into conformity with the Final Completion Date set forth therein, the costs of which shall be a Cost of the Work and not exceed the GMP. If the delay is an Excusable Delay, CITY shall either (a) authorize an equitable extension in the Schedule to account for such delay, and equitably adjust the GMP on account of such delay, to the extent permitted by Article 6; or (b) request that CONTRACTOR prepare a recovery schedule showing how (if possible) CONTRACTOR can achieve Substantial Completion by the date shown on the Schedule (as modified), and equitably adjust the GMP in accordance with the Change Order provisions of this Agreement on account of any extraordinary activities required of CONTRACTOR on account of such recovery schedule. Schedule float (total float) shall be owned by CITY. As float is an expiring resource, if the Work is delayed on the critical path due to a delay caused by the CONTRACTOR and/or Architect/Engineer, the CONTRACTOR may not use any float created by such a delay on any other path without the express written approval of CITY.

4.3 Pre-construction Activities. Within thirty (30) Days after execution of this Agreement, CONTRACTOR shall submit to CITY for review a detailed schedule of pre-construction 20 [3/21/25]

activities, by expanding the pre-construction activities set forth on the Schedule. This pre- construction schedule shall be prepared using the CPM, and shall show in sufficient detail the starting and completion times sequences of Subcontract award activities of CONTRACTOR, and identify all interface activities of CITY.

4.4 Extensions of Time.

4.4.1 General. An extension in the scheduled date of Final Completion will only be granted in the event of Excusable Delays affecting Work activities on the critical path.

4.4.2 Excusable Delays. Subject to 4.4.1 and 4.5.2, to the extent any of the following events results in an actual delay in the Work affecting Work activities on the critical path, such shall constitute an "Excusable Delay" (to the extent not set forth below, a delay will be considered an "Inexcusable Delay").

4.4.2.1 Failure or inability of CITY to make available any or all of the Site in accordance with the requirements of the Schedule.

4.4.2.2 Failure or inability of CITY or CONTRACTOR to obtain necessary zoning changes, variances, code changes, permits or approvals from any governmental authority, or failure to obtain any street or alley vacations required for the performance of the Work, except to the extent due to the fault or neglect of CONTRACTOR.

4.4.2.3 Delays resulting solely from the acts or omissions of Separate Contractors; provided however, only to the extent Separate Contractors perform their work improperly and not in accordance with any applicable critical path schedule.

4.4.2.4 Delays resulting from Force Majeure.

4.4.2.5 Differing, unusual or concealed site conditions that could not reasonably have been anticipated by CONTRACTOR in preparing the Schedule.

4.4.2.6 Delays resulting from the existence or discovery of Hazardous Materials on the Site not brought to the site by CONTRACTOR or any Subcontractor.

4.4.2.7 Delays resulting from changes in Applicable Laws occurring after the date of execution of this Agreement.

4.4.2.8 Delays occurring solely due to the acts or omissions of CITY and those within the control of CITY, including, but not limited to, Separate Contractors.

4.4.2.9 Delays resulting from weather conditions, which shall be determined as follows: Should CONTRACTOR prepare to begin work at the regular starting time of any working day on which inclement weather, or the conditions resulting from the weather, prevents the Work from beginning at the usual starting time and the crew is dismissed as a result thereof and CONTRACTOR does not proceed with at least 75% of the normal labor and equipment force engaged in the current operations for at least 60% of the total daily time being spent, 21 [3/21/25]

CONTRACTOR will not be charged for a working day, even if the conditions change during the course of the day. At the start of such days, CONTRACTOR shall notify CITY if CONTRACTOR believes that inclement weather or conditions resulting from the weather exist. A non-working day determination of such conditions shall be made by CITY, who will immediately notify CONTRACTOR.

4.4.2.10 Delays resulting from unproductive work days, which shall be determined as follows: When CONTRACTOR is prevented from working on current operations due to site conditions, CITY action, or force majeure for at least 60% of the total daily time on the controlling operations. Controlling operations are determined by the critical path method schedule described in the applicable CITY construction standards. The critical path schedule used in this determination shall be no more than thirty (30) days old. CONTRACTOR shall notify CITY if CONTRACTOR believes an unproductive work day exists upon discovery of such condition. A non-working day determination of such conditions shall be made by CITY, who will immediately notify CONTRACTOR.

4.4.3 Requirements for Schedule Amendment due to Excusable Delays. In order to obtain an extension of time due to an Excusable Delay, CONTRACTOR shall comply with the following requirements:

4.4.3.1 CONTRACTOR shall notify CITY of the Excusable Delay as soon as practicable, but in no event more than four (4) Business Days after CONTRACTOR becomes aware of the occurrence of the Excusable Delay. Such notice shall describe the Excusable Delay and shall state the approximate number of Days CONTRACTOR expects to be delayed. After the cessation of the Excusable Delay, CONTRACTOR shall notify CITY of the number of Days CONTRACTOR believes that its activities were in fact delayed by the Excusable Delay. In the event that the delay arises as a result of a Change Order request by CITY, the request for an extension of time contained in the resulting Change Order proposal shall be deemed sufficient for purposes of this subsection.

4.4.3.2 CONTRACTOR shall demonstrate to the satisfaction of CITY that the Excusable Delay in fact delayed the critical path for performance of the Work (by use of CPM analysis). Any delay that impacts the CPM will be presented to the Project Manager at the monthly meeting, and prior to completion of each activity.

4.4.4 Decision by CITY. Within thirty (30) Days after cessation of an event giving rise to either an Excusable Delay or Inexcusable Delay, the parties will use good faith efforts to agree on the extent to which the Work has been delayed and whether the delay is an Excusable Delay or an Inexcusable Delay. In the absence of agreement between the parties as to the then current status of Excusable Delays and Inexcusable Delays, CITY will provide CONTRACTOR with written notice of CITY's determination of the respective number of Days of Excusable Delay and/or Unexcusable Delay within ten (10) Days after receipt by CITY of CONTRACTOR's written request for such determination. The issuance by CITY of such a determination shall not, however, be deemed a concurrence by CONTRACTOR of the matters set forth therein, and CONTRACTOR may invoke the dispute resolution procedures with respect to such determination. Pending completion of dispute resolution procedures, CONTRACTOR may take such acceleration or other measures required on account of CITY's determination of 22 [3/21/25]

Inexcusable Delay, and if completion of the dispute resolution procedures results in CITY's determination being changed to Excusable Delay, the costs associated with such measures shall be paid by CITY as an increase to the GMP in accordance with the Change Order provisions of this Agreement.

4.5 Adjustment in GMP on Account of Extensions of Time.

4.5.1 Certain Excusable Delays. Section 4.5 governs the extent to which CONTRACTOR is entitled to an extension of time due to Excusable Delays. Provisions governing the payment of additional compensation on account of such Excusable Delays, (if any) are set forth in Article 6.

4.5.2 Concurrent Delays. To the extent CONTRACTOR is entitled to an extension of time due to an Excusable Delay, but the performance of the Work would have been suspended, delayed or interrupted by the fault or neglect of CONTRACTOR, any subcontractor and/or by an Inexcusable Delay, CONTRACTOR shall not be entitled to any additional costs for the period of such concurrency.

4.6 Liquidated Damages.

4.6.1 General. CONTRACTOR and CITY acknowledge that in the event that CONTRACTOR fails to achieve Final Completion of the Project by the date established, CITY will incur substantial damages that shall be incapable of accurate measurement. Nonetheless, the parties acknowledge that on the date of this Agreement, the amount of liquidated damages set forth below represents a good faith estimate as to the actual potential damages that CITY would incur as a result of late Completion of the Project. Such liquidated damages shall be in-lieu of actual damages resulting from late completion. The amount of the liquidated damages calculated hereunder does not include any penalty.

4.6.2 Amount of Liquidated Damages. If CONTRACTOR fails to achieve Final Completion of the Work on or before the Notice of Completion date, as adjusted for Excusable Delays, CONTRACTOR shall pay to CITY liquidated damages in the amount of $5000.00 (five thousand dollars) per Day for each calendar day the date of Final Completion is unexcusably delayed up to a maximum of two percent (2%) of the total Agreement price. Payment of liquidated damages shall be made contemporaneously with CITY's required payment to CONTRACTOR, and such payments may be offset against each other.

ARTICLE 5

PAYMENT AND COMPLETION

5.1 Guaranteed Maximum Price (“GMP”) and GMP Shared Savings. CITY shall pay for CONTRACTOR's performance under this Agreement (as described in Exhibit A hereto) on a fixed price lump sum basis, as adjusted by Change Order/Directive in accordance with the Contract Documents. CONTRACTOR bears the risk of its increased costs due to market price 23 [3/21/25]

increases (including escalating costs for materials) but not including direct impacts from the imposition of tariffs which will be documented by CONTRACTOR and reimbursed by CITY.

5.1.1 Shared Savings. [reserved]

5.2 Schedule of Values. Before the first Application for Payment, CONTRACTOR shall submit to CITY, and CITY shall approve, a schedule of values, setting forth the various portions of the Work, and the portions of the GMP allocated to each portion. This schedule of values shall be used as a basis for payment.

5.3 Applications for Payment. CONTRACTOR shall deliver to CITY not more than once each month an Application for Payment covering the Cost of Work and Fee applicable to the Work performed during the immediately preceding month. With each Application for Payment CONTRACTOR shall submit such evidence as may be necessary to demonstrate costs incurred on account of Cost of the Work during such month and the percentage of completion of each category of Work. CITY may reject requests for payment, or portions thereof, for Work, or portions thereof, not performed or completed.

5.4 Amount of Progress Payments. CITY shall pay CONTRACTOR the actual Cost of the Work and Fee, if any, through the period covered by the Application for Payment, less Retention as set forth in Section 5.5 below, provided that the aggregate payment amount before retention will not exceed the percentage of completion of the Work multiplied by the GMP (excluding items of the GMP not subject to retention). CITY may additionally withhold from progress payments such amounts pursuant to stop payment notice claims as required by law and CITY administrative regulation 4.01.

5.5 Retention; Escrow Agreement; Final Payment. Five percent (5%) Retention shall be withheld from each progress payment until the expiration of thirty-five (35) days following the recordation of the notice of completion; provided however, City shall continue to retain such amount as required by law and/or CITY administrative regulation 4.01. CONTRACTOR may elect to establish an escrow account for securities in-lieu of the five percent (5%) Retention in a form of escrow agreement compliant with law and subject to approval by the City Attorney (form of escrow agreement is attached as Exhibit D). Release of Retention monies shall constitute the Final Payment.

5.6 Early Release of Subcontractor Retention. [reserved]

5.7 Payment for On-Site and Off-Site Stored Materials. [reserved]

5.8 Title to Construction Work. CONTRACTOR warrants that title to all Construction Work covered by an Application for Payment shall pass to CITY no later than the time of payment. CONTRACTOR further warrants that upon submittal of an Application for Payment, all Construction Work for which Applications for Payment have been previously issued and payments received from CITY shall, to the best of CONTRACTOR's knowledge, information and belief, be free and clear of liens, claims, security interests or encumbrances in favor of 24 [3/21/25]

CONTRACTOR, Subcontractors, material suppliers, or other persons or entities making a claim by reason of having provided labor, materials or equipment relating to the Construction Work.

5.9 Withholding of Payment. CITY may withhold payment on account of an Application for Payment if required or authorized by any Applicable Law, or to the extent necessary to protect CITY from loss because of:

5.9.1 defective Work not remedied;

5.9.2 third party claims filed or reasonable evidence indicating probable filing of such claims;

5.9.3 failure of CONTRACTOR to make payments of undisputed amounts to Subcontractors for labor, materials or equipment;

5.9.4 damage to CITY or a Separate Contractor caused by the fault or neglect of CONTRACTOR to the extent not reimbursed by insurance; or

5.9.5 reasonable evidence that the Work will not be Substantially Completed within the Contract Time due to Inexcusable Delay, and that the unpaid balance of the GMP would not be adequate to cover liquidated damages for the anticipated Inexcusable Delay.

5.10 Failure of Payment; Interest. In accordance with Public Contract Code §20104.50, CITY shall pay CONTRACTOR interest on any progress payment, which is made by CITY more than thirty (30) days after CITY receives an undisputed and properly submitted written payment request. Said interest shall be equal to the rate set forth in Code of Civil Procedure §685.010(a), and shall begin to accrue upon the expiration of said thirty (30) day period. Any written request for a progress payment which CITY determines to be disputed, improper or not suitable for payment for any reason shall be returned to CONTRACTOR within seven (7) days after receipt by CITY, along with a written statement of the reason or reasons why such request is disputed, improper or not suitable for payment.

5.11 Occupancy by CITY Prior to Acceptance. CITY reserves the right to Beneficial Occupancy and without charge by CONTRACTOR. In those areas of the Work which are completed, CITY may store materials, equipment, and supplies, and may perform partial operation.

5.12 Substantial Completion. When CONTRACTOR considers the entire Work complete and ready for its intended use, CONTRACTOR shall certify in writing to CITY that the entire Work is substantially complete by providing CITY with a Certificate of Substantial Completion.

Within a reasonable time thereafter, CITY and CONTRACTOR shall make an inspection of the Work to determine the status of completion. If CITY does not consider the Work substantially complete, CITY will notify CONTRACTOR in writing giving reasons therefor. If CITY considers the Work substantially complete, CITY will accept a corresponding partial Certificate of Substantial Completion. There shall be attached to the Certificate a Punch List of items to be completed or corrected before Final Acceptance and Final Payment. 25 [3/21/25]

5.13 Final Completion. When the Work is fully completed, CONTRACTOR shall provide CITY with a Certificate of Final Completion and shall request final inspection in writing.

Additionally, CONTRACTOR shall provide legally effective releases or waivers satisfactory to CITY of all lien rights arising out of or liens filed in connection with the Work. Within ten (10) calendar days of receipt of such completed request form, CITY shall make final inspection. If following final inspection CITY determines that the Work (including all Punch List items) has been fully completed, CITY will process a Notice of Completion. If CITY determines that the Work is not complete after receipt of certification from CONTRACTOR, CONTRACTOR shall be notified in writing of deficiencies. After the deficiencies have been corrected, the procedure for final inspection as set forth above shall again be initiated by CONTRACTOR. In the event CITY determines the Work is fully completed, CITY shall initiate process of attaining a notice of completion.

5.13.1 Waiver of Claims at Final Payment. Acceptance of final payment by CONTRACTOR shall constitute a waiver of all claims by CONTRACTOR, except those previously made in writing and identified as unsettled at the time of final payment.

5.14 Construction Allowance Items. [reserved]

5.15 Superintendent. CONTRACTOR shall employ a competent superintendent and necessary assistants who shall be in attendance at the Project site during performance of the Construction Work. The superintendent shall represent CONTRACTOR, and communications given to the superintendent shall be as binding as if given to CONTRACTOR.

5.16 Documents and Samples at the Site. CONTRACTOR shall maintain at the site for CITY one record copy of the drawings, specifications, addenda, Change Order and other Modifications, in good order and marked currently to record changes and selections made during construction, and in addition approved Shop Drawings, Product Data, Samples and similar required submittals. CONTRACTOR shall also prepare one reproducible set of as-built drawings. These shall be provided to CITY upon completion of the Work.

5.17 Contingency. [reserved]

ARTICLE 6
CHANGES IN THE WORK; CLAIMS

6.1 Changes. Changes in the Work shall be performed under applicable provisions of the Contract Documents. If unit prices are stated in the Contract Documents or subsequently agreed upon, and if quantities originally contemplated are so changed in a proposed Change Order or Change Directive that application of such unit prices to quantities of Work proposed will cause substantial inequity to CITY or CONTRACTOR, the applicable unit prices for such change order/directive shall be equitably adjusted. No GMP adjustment on account of a Change Order shall include CONTRACTOR's or Subcontractor's profit, Fee, home office overhead or a formula allocation of indirect costs unless otherwise specifically allowed hereunder. 26 [3/21/25]

6.2 Change Directives. The following procedures shall apply with respect to Change Directives:

6.2.1 Upon receipt of a Change Directive signed by CITY, CONTRACTOR shall promptly proceed with the change in the Work involved and advise CITY of CONTRACTOR's agreement or disagreement with the method, if any, provided in the Change Directive for determining the proposed adjustment in the GMP or the Schedule. If CONTRACTOR receives a written communication signed by CITY which CONTRACTOR believes is a Change Directive but is not so identified, it shall not proceed with the change in the Work until it receives from CITY a written confirmation that such communication is in fact a Change Directive.

6.2.2 A Change Directive signed by CONTRACTOR indicates the agreement of CONTRACTOR with the contents thereof, and shall convert the Change Directive to a Change Order.

6.2.3 If CONTRACTOR does not respond promptly or disagrees with the method for adjustment in the GMP or Schedule, the method and adjustment shall be determined as provided in Sections 6.5 or 6.10 below, as applicable. In such case, CONTRACTOR shall keep and present, in such form as CITY may request, an itemized accounting, together with appropriate supporting data.

6.2.4 Pending final determination of cost to CITY, amounts not in dispute shall be included in Applications for Payment. The amount of credit to be allowed by CONTRACTOR to CITY for a deletion or change which results in a net decrease in the GMP shall be actual net cost. When both additions and credits covering related Work or substitutions are involved in a change, the allowance for Fee shall be figured on the basis of net increase, if any, with respect to that change.

6.2.5 If CITY and CONTRACTOR do not agree with the adjustment in the Schedule or the GMP, such disagreement shall be submitted for dispute resolution in accordance with the provisions of this Contract.

6.3 Change Proposals. If CITY requests CONTRACTOR to submit a Change Proposal which would entitle CONTRACTOR to an increase in the GMP for costs of preparation of such Change Proposal pursuant to the provisions of this Section 6.3, CONTRACTOR shall first estimate the costs of preparing such Change Proposal and inform CITY in writing of such costs.

CITY shall then direct CONTRACTOR either to proceed with the Change Proposal or cancel the Change Proposal. If CITY directs CONTRACTOR to proceed with the Change Proposal and then elects not to proceed with the Change Order contemplated therein, a Change Order shall be issued to reimburse CONTRACTOR for costs reasonably incurred by CONTRACTOR on account of such Change Proposal, but only to the extent the Change Order contemplated by such Change Proposal involves a material change to the scope of the Work requiring modification to one or more systems which have been designed and approved in accordance with the standards set forth in the technical specifications. To the extent the preparation of such Change Proposal impacts the Schedule (e.g., other Work is suspended pending a decision on such Change 27 [3/21/25]

Proposal or the Design Work is delayed due to the preparation of the Change Proposal), an equitable adjustment in the Schedule shall be made.

6.4 Claims. CONTRACTOR shall submit any claims for additional compensation to CITY in writing. The claim shall set forth the reason(s) that CONTRACTOR believes additional compensation will or may be due, the nature of the costs involved, and insofar as possible, the amount of the potential claim. The notice must be given to the Project Manager prior to the time that CONTRACTOR shall have performed the work giving rise to the potential work for additional compensation, if based on an act or failure to act by CITY, or in all other cases within fifteen (15) calendar days after happening of the event, thing or occurrence giving rise to the potential claim. Any and all Claims not presented as required herein shall be waived.

6.5 Change Orders Increasing or Decreasing Scope.

6.5.1 Increased Scope. With respect to Change Orders which increase the Scope of Work described on Exhibit F, are not due to the errors or omissions of CONTRACTOR and are not attributable to Excusable Delays or the contingencies set forth in Section 6.6 below, the GMP shall be increased by the following "Scope Change Costs":

6.5.1.1 Construction Work and Mark Ups.

6.5.1.1.1 The estimated increase in the Cost of the Work attributable to the Change Order and which would not have been incurred but for the Change Order and/or Work Directive. In addition, CONTRACTOR may add a markup of up to ten percent (10%), subject to the discretion of the Project Manager, to the increase in the Cost of the Work due to the Change Order. This markup shall constitute full compensation for all delay costs, overhead costs and profit. The GMP shall be revised accordingly.

6.5.1.1.2 When Change Order work is performed by a
Subcontractor(s), each Subcontractor may add a markup of up to ten percent (10%), subject to the discretion of the Project Manager, to their direct costs for labor, materials and equipment used in performing the Change Order work. The GMP shall be revised accordingly.

6.5.2 Decreased Scope. With respect to Change Orders, which decrease the Scope of Work described on Exhibit F, the GMP shall be decreased by the Cost of Work attributable to such Change Order and/or Work Directive. Furthermore, if the Change Order deletes a part of the Scope of Work, CONTRACTOR shall be entitled to retain a value of five percent (5%) of the full value of the reduction in Cost of Work attributable only to the portion of the Scope of Work deleted from the Scope of Work. The GMP shall be revised accordingly.

6.6 Change Orders on Account of Contingencies. With respect to Change Orders which are attributable to the following contingencies, the GMP shall be adjusted (increased or decreased) by the following "Contingency Costs,'' consisting of the following:

6.6.1 With respect to new or increased taxes arising after the date of this Agreement (other than taxes assessed based on the income of CONTRACTOR), the Change Order shall 28 [3/21/25]

consist of the incremental amount of such new or increased taxes only. With respect to reductions in taxes arising after the date of this Agreement (other than taxes assessed based on the income of CONTRACTOR), the Change Order shall consist of the incremental amount of such reduced taxes only.

6.6.2 With respect to increases or decreases in fees for permits or other governmental certificates or instruments arising after the date of this Agreement, the Change Order shall consist of the incremental amount of such increases or decreases. To the extent this Agreement states that a permit or certificate is not required and CONTRACTOR is later required to procure such permit or certificate, all out-of-pocket costs reasonably associated therewith shall be included in the Change Order.

6.7 Change Orders on Account of Excusable Delay. With respect to Change Orders, which are attributable to Excusable Delays, and subject to the exceptions set forth in Section

6.7.3 below, the GMP shall be increased by the following "Delay Costs":

6.7.1 Construction Work.

6.7.1.1 Increased allowable labor costs resulting from wage increases paid due to the delay;

6.7.1.2 Premiums for overtime and extra shifts incurred in accelerating the Work, but only if acceleration is required in advance by CITY:

6.7.1.3 Proven increased material costs;

6.7.1.4 Additional general conditions costs which would not have been incurred but for the delay (itemized, and not based on a formula allocation);

6.7.1.5 Demobilization and remobilization costs; and

6.7.1.6 Additional items of Cost of the Work attributable to the Excusable Delay and which would not have been incurred but for the Excusable Delay.

6.7.2 Intentionally left blank.

6.7.3 Exceptions. The following exceptions to the provisions of Section 6.7.1 above shall apply:

6.7.3.1 With respect to the Excusable Delay described in Section 4.4.2.1, the cost described in Section 6.7.1 shall not be compensable delay costs if such Excusable Delay occurs prior to the commencement of the Construction Work.

6.7.3.2 With respect to the Excusable Delay described in Section 4.4.2.2, the cost described in Section 6.7.1 shall not be compensable delay costs if such Excusable Delay occurs prior to the commencement of the Construction Work.

29 [3/21/25]

6.7.3.3 With respect to the Excusable Delay described in Section 4.4.2.4, costs incurred in connection with such delay are chargeable against the Cost of the Work but shall not increase the GMP.

6.7.3.4 With respect to the Excusable Delay described in Section 4.4.2.5, in addition to the compensation provided in Section 6.7.1, CONTRACTOR shall be entitled to the additional costs set forth in Section 6.10.

6.7.3.5 With respect to the Excusable Delay described in Section 4.4.2.7, additional compensation shall only be paid if the change in Applicable Law is not a change in law of general application (e.g., CAL/OSHA), but is a change in law specifically affecting the Project.

6.8 Force Majeure. There shall be no additional compensation to CONTRACTOR on account of Force Majeure.

6.9 Intentionally left blank.

6.10 Change Orders on Account of Differing Site Conditions. If CONTRACTOR encounters conditions described in Section 4.4 which constitute Excusable Delay, in addition to the increase in the GMP on account of delay costs incurred by CONTRACTOR (as described in Section 6.7.1), the GMP shall also be increased by the additional Cost of the Work attributable to such conditions which would not have been incurred but for such conditions.

6.11 Time Extensions on Account of Change Orders. CONTRACTOR shall be entitled to a time extension in connection with any Change Order to the extent its time of performance is extended due to such Change Order. CONTRACTOR shall present to CITY a CPM analysis showing how the Change Order affects the critical path of the Work.

ARTICLE 7

CORRECTION OF WORK

7.1 Correction of Work Prior to Completion. Prior to the date of Final Completion, CONTRACTOR shall correct Work which (a) CITY reasonably rejects as being defective or nonconforming to the requirements of the Contract Documents in a written notice delivered to CONTRACTOR or (b) CONTRACTOR recognizes is defective or nonconforming to the Contract Documents. If other portions of the Work are adversely affected by or are damaged by such defective Work, CONTRACTOR shall also correct, repair or replace such affected or damaged Work, as well as any other property of CITY or others damaged by such defective or nonconforming Work. Prior to the date of Final Completion, the cost of correcting any damaged or defective work shall be paid as a Cost of the Work.

7.2 Correction of Work After Completion. For defects identified by CITY and for which CITY has notified CONTRACTOR within a period of twelve (12) months after the date of Final Completion, or within such longer period as may be provided by special warranties contained in 30 [3/21/25]

the Contract Documents, CONTRACTOR shall re-execute, correct, repair or replace all Work found to be defective or nonconforming to the Contract Documents (whether arising from a design or construction defect, error, omission or deficiency). If other portions of the Work are adversely affected by or damaged by such defective Work, CONTRACTOR shall also correct, repair or replace such affected or damaged Work, as well as any other property of CITY or others damaged by such defective or nonconforming Work.

7.3 Acceptance of Nonconforming Work. If CITY prefers to accept Work, which is not in accordance with the requirements of the Contract Documents, CITY may do so instead of requiring its removal and correction, in which case the GMP will be reduced as appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made.

7.4 No Effect on Limitations. Nothing contained in this Article shall be construed to establish a period of limitation with respect to other obligations, which CONTRACTOR may have under the Contract Documents.

ARTICLE 8

SUBCONTRACTORS

8.1 Subcontracts

8.1.1 Incorporation of Contract Documents. CONTRACTOR may enter into Subcontracts with various Subcontractors for portions of the Work. The Subcontracts shall require each Subcontractor, to the extent of the Work to be performed by such Subcontractor, to assume towards CONTRACTOR all the obligations and responsibilities which CONTRACTOR assumes towards CITY. All Subcontracts shall incorporate the terms of this Agreement and the Contract Documents to the extent applicable to the Work to be performed by the Subcontractor.

8.1.2 Approval of Subcontractors. Those portions of the Construction Work that the CONTRACTOR does not intend to perform with CONTRACTOR's own personnel shall be performed under Subcontracts. A proposed list of Subcontractors shall be submitted to CITY for approval. Proposed Subcontractors will be deemed accepted unless CITY objects in writing within five (5) days after submission by CONTRACTOR.

ARTICLE 9
INSURANCE AND BONDS; INDEMNIFICATION

9.1 Insurance to be provided by CONTRACTOR:

A. Evidence of Coverage. CONTRACTOR shall, at all times, maintain in full force and effect at a minimum the insurance required by this section; and CONTRACTOR shall not allow any subcontractor to commence Work until similar insurance required of the subcontractor has been obtained and filed. An original Certificate of Insurance, and copies of all required endorsements, all in a form approved by the Risk Manager, evidencing all required coverage or 31 [3/21/25]

policies shall be filed after the award of the bid and prior to approval of the Contract by the City Council. CONTRACTOR shall provide ten (10) Days prior written notice to CITY of any reduction of coverage limits or cancellation of the coverage or policies shall be given to the City of Roseville as Certificate holder.

B. Qualifying Insurers. With the exception of the State Compensation Insurance Fund, all required insurance policies shall be issued by companies licensed to do business in the State of California and who hold a current policy holders alphabetic and financial size category rating of not less than AVII according to the most recent issue of Best's Insurance Reports.

C. Insurance Required. Commercial General Liability, automobile liability, and worker's compensation insurance shall be maintained as follows:

1. Commercial General Liability $2,000,000 each occurrence Minor Construction Project $4,000,000 aggregate
(Projects under $1,000,000)

Personal Injury:
$2,000,000 each occurrence
$4,000,000 aggregate

Commercial General Liability for $5,000,000 each occurrence Major Construction Projects $10,000,000 aggregate
(Projects over $1,000,000) Personal Injury:
$5,000,000 each occurrence
$10,000,000 aggregate

2. Professional Liability (errors and $2,000,000 per claim omissions) $4,000,000 aggregate

The Commercial General Liability policy shall include coverage or endorsements for:
a. Completed operations.
b. Losses related to independent contractors, products and equipment. c. Explosion, collapse and underground hazards.

The Commercial General Liability Insurance shall include the following, copies of which shall be provided:
a. Inclusion of the City of Roseville, and the California Department of Water Resources and their officers, agents, employees and volunteer, as additional insured (except for workers’ compensation as respects services or operations under the Contract. The additional insured endorsement for the general liability policy shall be at least as broad as the Insurance Services Office (“ISO”) CG 20 38 04 13 or an equivalent, blanket endorsement or section of the policy.

Endorsements must include coverage for on-going and completed operations. 32 [3/21/25]

Endorsements shall cover the City of Roseville, and the California Department of Water Resources and their officers, agents, employees, and volunteers. b. Cross liability and severability of interest clauses providing that the insurance applies separately to each insured except with respect to the limits of liability. c. Stipulation that the insurance is primary and noncontributory, as evidenced by a separate endorsement (CG 20 01 04 13 or an equivalent) or section of the policy, and that neither CITY nor its insurers will be called upon to contribute to a loss. d. Such insurance shall specifically cover the contractual liability of the CONTRACTOR.
e. Any available insurance proceeds in excess of the specified minimum insurance coverage requirements and limits shall be available to the additional insureds.

Furthermore, the requirements for coverage and limits shall be: (1) the minimum coverage and limits specified in this Agreement; or (2) the full coverage and maximum limits of any insurance proceeds available to the named insureds, whichever is greater.
f. Waiver of subrogation endorsement.
g. CONTRACTOR shall furnish a certificate for the period covered.

SPECIAL NOTICE - CLAIMS MADE COVERAGE:

Liability insurance coverage may not be written on a "claims made" basis. The Certificate of Insurance must clearly provide that the coverage is on an "occurrence" basis.

2. Comprehensive Automobile Liability for bodily injury (including death) and property damage which provides total limits of not less than One Million Dollars ($1,000,000) combined single limits per accident, applicable to all owned, non-owned, and hired vehicles.

3. Statutory Workers' Compensation and Employer's Liability Insurance, including a waiver of subrogation endorsement and a Broad Form "All-States" Endorsement for all employees engaged in services or operations under the Contract. The employer's liability insurance shall provide limits of not less than One Million Dollars ($1,000,000) per occurrence.

Both the worker's compensation and employer's liability policies shall contain the Insurer's waiver of subrogation in favor of CITY, its officers, agents, employees, and volunteers.

4. Builder's Risk/Course of Construction Insurance: CONTRACTOR shall be responsible for all loss, damage or destruction whatsoever to the Work called for by this Contract until the approval of a Notice of Completion. CONTRACTOR shall secure "All Risk" type of builder's Risk Insurance of the type covering one hundred percent (100%) of the value of the Work performed under this Contract (the value is presumed to be the Contract plus the purchase price of the relocated equipment specified in Attachment I Section 3.2) and all materials, equipment, or other items to be incorporated therein while the same are located at the construction site, a bonded warehouse, or its place of manufacture. At any time, the policy shall cover the value of the Work completed. The policy shall cover hazards including the losses due to fire, explosion, hail, rain, lightning, flood (separate insurance as needed), vandalism, malicious mischief, wind, collapse, aircraft, and smoke.

33 [3/21/25]

The policies providing such insurance shall name CITY as a loss payee as its respective interests may appear, and certified copies of such policies shall be filed with CITY. The maximum deductible allowable under the Builder's All Risk policy shall be five percent (5%) of the Contract amount.

Builder's Risk Insurance is not required for coverage of losses in excess of five percent (5%) of the Contract amount for damages resulting from earthquake in excess of a magnitude of

3.5 on the Richter scale, or tidal waves. Coverage in the amount of five percent (5%) of the Contract amount for such losses is required.

D. Other Insurance Provisions.

1. The requirements of the Contract Conditions as to types and limits of insurance coverage to be maintained by CONTRACTOR, and any approval of insurance by CITY, are not intended to, and shall not in any manner limit or qualify the liabilities and obligations otherwise assumed by CONTRACTOR pursuant to the Contract, including, but not limited to, the provisions concerning indemnification, nor preclude CITY from taking any other action available to it under any other provision of the Contract or law.

2. CITY acknowledges that some insurance requirements contained in the Contract Conditions may be fulfilled by self-insurance on the part of CONTRACTOR. However, this shall not in any way limit liabilities assumed by CONTRACTOR under the Contract. Any self- insurance must be approved in writing by CITY, in its sole discretion and shall not reduce the limits of liability. Any deductibles or self-insured retentions (“SIR”) must be declared on the certificate of insurance and approved by CITY in writing. Policies containing any SIR provision shall provide or be endorsed to provide that the SIR may be satisfied by either the named insured or CITY. CITY reserves the right to obtain a full certified copy of any insurance policy and endorsements. The failure to exercise this right shall not constitute a waiver of such right.

3. CONTRACTOR agrees to include in its contracts with all subcontractors the same requirements and provisions of this Contract, including the indemnity and insurance requirements, to the extent they apply to the scope of the subcontractor’s work. Furthermore, CONTRACTOR shall require its subcontractors to agree to be bound to CONTRACTOR and CITY in the same manner and to the same extent as CONTRACTOR is bound to CITY under this Contract. Additionally, CONTRACTOR shall obligate its subcontractors to comply with these same provisions with respect to any tertiary subcontractor, regardless of tier. A copy of CITY’s indemnity and insurance provisions will be furnished to the subcontractor or tertiary subcontractor upon request. Alternatively, CONTRACTOR may insure subcontractor(s) under its own policy.

4. CITY, its officers, agents, employees and volunteers are to be covered as insureds with respect to liability arising out of automobiles owned, leased, hired or borrowed by or on behalf of CONTRACTOR; and with respect to liability arising out of work or operations performed by or on behalf of CONTRACTOR including materials, parts or equipment furnished in connection with such work or operations. Coverage shall not extend to any indemnity coverage for the active negligence of the additional insured in any case where an agreement to 34 [3/21/25]

indemnify the additional insured would be invalid under California Insurance Code Section 11580.04. In addition, the insurance policy may not contain language which prohibits additional insureds or other insurers from satisfying the self-insured retention or deductible.

5. The limits of insurance required in this Contract may be satisfied by a combination of primary and excess insurance. Any excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and noncontributory basis for the benefit of CITY (if agreed to in a written contract) before the CITY’s own insurance shall be called upon to protect it as a named insured.

6. Unless provided by CONTRACTOR, CONTRACTOR shall require its Architect/Engineer to provide professional liability (errors and omissions) insurance (certificate and additional insured endorsement).

7. CITY RESERVES THE RIGHT TO WITHHOLD ANY PROGRESS

PAYMENTS TO CONTRACTOR IN THE EVENT OF NONCOMPLIANCE WITH ANY INSURANCE REQUIREMENTS.

9.2 Insurance to be provided by CITY. [not applicable]

9.3 Payment, Performance and Warranty Bonds. CONTRACTOR shall furnish and deliver to CITY Performance, Labor & Materials, and Warranty Bonds issued by a surety prior to, and as a condition precedent to, commencement of the Construction Work on the Site; provided, however, the Warranty Bond shall be waived if such bond is not required pursuant to CITY’s request for proposals for the Project. The Payment and Performance Bonds shall be in a penal sum equal to one hundred percent (100%) of the GMP, and the Warranty Bond shall be in the penal sum equal to ten percent (10%) of the GMP. All bonds shall be in the form as set forth in Exhibit E hereto. All premiums for the Performance, Labor & Materials, and Warranty Bonds shall be a Cost of the Work. CITY shall have the right to withhold any payment(s) under this Agreement until CONTRACTOR has fully complied with this sub-section.

9.4 Indemnification. To the fullest extent allowed by law, CONTRACTOR shall defend, indemnify, and hold harmless, CITY, its officers, employees, agents, and volunteers, and each and every one of them, from and against all actions, damages, claims, losses, expenses or other liabilities of every type and description, including reasonable attorney fees, to which they may be subjected or put for personal injury, death, or property damage to the extent caused by the willful or reckless misconduct and/or any negligent or wrongful act or omission of CONTRACTOR, any Subcontractor, and anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable, CONTRACTOR does not assume any liability for the negligence of CITY regardless of whether active or passive.

CONTRACTOR’s responsibility for such defense and indemnity obligations shall survive the termination or completion of this Agreement for the full period of time allowed by law. The defense and indemnity obligations of this Agreement are undertaken in addition to, and shall not in any way be limited by, the insurance obligations contained in this Agreement.

35 [3/21/25]

9.5 Consequential Damages. Notwithstanding any other provision of this Agreement, and to the fullest extent permitted by law, neither the CITY nor CONTRACTOR, their respective officers, directors, partners, employees, contractors or subconsultants shall be liable to the other or shall make any claim for any incidental, indirect or consequential damages arising out of or connected in any way to the project or to this Agreement. This mutual waiver of consequential damages shall include, but is not limited to, loss of use, loss of profit, loss of business, loss of income, loss of reputation or any other consequential damages that either party may have incurred from any cause of action including negligence, strict liability, breach of contract and breach of strict or implied warrantee.

9.6 Limit of Liability. To the maximum extent permitted by law, the CITY agrees to limit CONTRACTOR’S liability for any and all claims, losses, costs, damages of any nature whatsoever or claims expenses from any cause or causes, including attorneys’ fees and costs and expert-witness fees and costs, so that the total aggregate liability of CONTRACTOR to the CITY shall not exceed the insurance coverage limits required by the Agreement. It is intended that this limitation apply to any and all liability or cause of action, however alleged or arising, unless otherwise prohibited by law.

ARTICLE 10

PROTECTION OF PERSONS AND PROPERTY

10.1 Safety Precautions and Programs.

10.1.1 Site Safety. CONTRACTOR shall be responsible for initiating, maintaining and providing supervision of safety precautions and programs in connection with the Work, and shall also comply with any and all insurance carrier-mandated safety requirements and programs.

10.1.2 Safety Notices. In connection with the performance of the Work, CONTRACTOR shall provide notices and comply with all Applicable Laws bearing on the safety of persons and property and their protection from damage, injury or loss.

10.2 Safety of Persons and Property.

It is the intent of the parties that CITY is not an exposing, creating, controlling, or correcting employer under California Labor Code Section 6400. In accordance with generally accepted fabrication and construction practices and all applicable Laws and Standards and Codes, CONTRACTOR shall have the authority and be solely and completely responsible for the safety of all property utilized and all persons performing under this Agreement. Moreover, the CONTRACTOR shall be the controlling employer and has the authority and responsibility to enforce safety for all fabrication, construction work, and Work performed under this Agreement.

The services of CITY’s contract administrator, if any, in conducting a review of CONTRACTOR’s performance under this Agreem ent is not intended to include a review of the adequacy of CONTRACTOR’s work methods, equipment or safety measures. If CITY and/or its contract administrator observes a safety violation related to the CONTRACTOR’s performance under this Agreement, then CI TY and/or its contract administrator will report the violation to the CONTRACTOR who is then responsible for assuring the violation is abated. 36 [3/21/25]

CONTRACTOR is hereby informed that work on this Project could be hazardous.

CONTRACTOR shall carefully instruct all personnel performing under this Agreement in potentially hazardous work areas as to potential dangers and shall provide such necessary saf ety equipment and instructions as are necessary to prevent injury to personnel and damage to property.

All Equipment, Work and materials provided under this Agreement shall be in strict accordance with all applicable Laws and Standards and Codes, and attention is drawn to the requirements of CAL/OSHA.

CONTRACTOR shall perform under this Agreement so as not to expose personnel to, or to discharge into the atmosphere from any materials brought to the Site by CONTRACTOR, smoke, dust, asbestos, toxic chemicals or other air contaminants in violation of applicable Laws and Standards and Codes.

10.2.1 Reasonable Precautions. CONTRACTOR shall take all precautions and implement all safety measures and requirements imposed by any Applicable Law. Without limiting the generality of the foregoing, CONTRACTOR shall take necessary precautions for the safety of, and shall provide necessary protection to prevent damage, injury or loss to:

10.2.1.1 Employees on the Work and other persons who may be affected thereby;

10.2.1.2 The Work and materials and equipment to be incorporated therein, whether in storage on or off the Site under care, custody or control of CONTRACTOR; and

10.2.1.3 Other property at the Site or adjacent thereto, such as trees, shrubs, lawns, walks, pavements, roadways, structures and utilities not designated for removal, relocation or replacement in the course of the Construction Work.

10.2.2 Safeguards. CONTRACTOR shall erect and maintain, as required by existing conditions and performance of the Work, reasonable safeguards for safety and protection, including posting danger signs and other warnings against hazards, promulgating safety regulations and notifying CITY and users of adjacent sites and utilities, and shall comply fully with the requirements of CAL/OSHA.

10.2.3 Use of Explosives. Use of explosives is prohibited, unless approved in advance in writing by CITY. CITY may impose reasonable conditions on the use of explosives.

10.2.4 Remedy of Damage. CONTRACTOR shall promptly remedy damage and loss to property referred to in Sections 10.2.1.2 and 10.2.1.3 caused in whole or in part by CONTRACTOR, or anyone employed by or in control of CONTRACTOR, or any Subcontractor. All costs incurred by CONTRACTOR in connection with its obligations under this Section shall be cost of the Work, but shall not increase the GMP.

10.2.5 Designation of Safety Coordinator. [reserved]
37 [3/21/25]

10.2.6 Loads. CONTRACTOR shall not load or permit any part of the Construction Work or the Site to be loaded so as to endanger its safety.

10.3 Security. CONTRACTOR shall take any and all precautions that may be reasonably necessary to render all portions of the Work, the Site and any adjacent areas affected by the Work secure in all material respects, to decrease the likelihood of accidents, and to avoid vandalism and other contingencies which are liable to delay the Work or give rise to claims or liabilities. CONTRACTOR shall furnish and install all necessary facilities to provide safe means of access to all points where Work is being performed. CONTRACTOR shall take all precautions and measures as may be reasonably necessary to secure the Project at all hours, including evenings, holidays and non-work hours. Such precautions may include provision of security guards.

10.4 Damage to Property at the Site. CONTRACTOR shall be responsible for any and all damage or loss to property at the Site, except to the extent caused by the acts or omissions of CITY or its representatives, agents or employees. If such damage or loss is caused by CONTRACTOR, payment of such costs as Cost of the Work shall be limited by the provisions of Section 2.20.5 hereof.

10.5 Damage to Property of Others. CONTRACTOR shall avoid damage, as a result of CONTRACTOR's operations, to existing sidewalks, curbs, streets, alleys, pavements, utilities, adjacent property, the work of Separate Contractors and the property of CITY. CONTRACTOR shall repair any such damage caused by the operations of CONTRACTOR.

10.6 Failure of CONTRACTOR to Repair Damage. If CONTRACTOR fails to commence the repair of damage to property as set forth in this Article, and/or diligently pursue such repair, then CITY, after ten (10) Days prior written notice to CONTRACTOR (provided CONTRACTOR has not commenced such repair during such ten (10) Day period), may elect to repair such damages with its own forces and to deduct from payments due or to become due to CONTRACTOR amounts paid or incurred by CITY is correcting such damage.

10.7 Emergencies. In an emergency affecting the safety of persons or property, CONTRACTOR shall act, at CONTRACTOR's discretion, to prevent threatened damage, injury or loss. Additional costs or extensions of time caused by CONTRACTOR on account of an emergency not caused by the fault or neglect of CONTRACTOR shall be determined as provided in Section 6.2 hereof.

ARTICLE 11

DISPUTES

11.1 Disputes between CITY and CONTRACTOR. In the event of any dispute arising between CITY and CONTRACTOR regarding any part of the Contract or the Contract Documents, or the Parties’ obligations or performance thereunder, and subject to any claims presentation requirements set forth in the Contract Documents, either Party may institute the 38 [3/21/25]

dispute resolution procedures set forth herein. The Parties shall continue performance of their respective obligation hereunder notwithstanding the existence of a dispute.

11.2 Dispute Resolution Procedures. CONTRACTOR must submit all claims as defined in and in accordance with the claim resolution process set forth in Section 9204 of the Public Contract Code. Each such claim must be sent to CITY by registered mail or certified mail with return receipt requested and must contain reasonable documentation to support the claim. All claims must be received prior to acceptance of the Work and will be handled in accordance with the procedures set forth in Section 9204 of the Public Contract Code.

ARTICLE 12
EVENTS OF DEFAULT AND REMEDIES; TERMINATION

12.1 CONTRACTOR Events of Default. The following shall be considered "CONTRACTOR Events of Default":

12.1.1 If CONTRACTOR fails or neglects to carry out the Work in accordance with the provisions of the Contract Documents, and fails, after seven (7) Days notice from CITY, to commence a cure to correct such failure or neglect and thereafter diligently pursue such cure to completion;

12.1.2 If CONTRACTOR materially breaches this Agreement and fails, after seven (7) Days notice from CITY, to commence a cure to correct such breach and thereafter diligently pursue such cure to completion (such breach to include, but not be limited to, failure to make payment to Subcontractors for materials or labor in accordance with the respective agreements between CONTRACTOR and the Subcontractors or violation of Applicable Laws);

12.1.3 If a custodian, trustee or receiver is appointed for CONTRACTOR, or if CONTRACTOR becomes insolvent or bankrupt, is generally not paying its debts as they become due or makes an assignment for the benefit of creditors, or CONTRACTOR causes or suffers an order for relief to be entered with respect to it under applicable bankruptcy law or applies for or consents to the appointment of a custodian, trustee or receiver for CONTRACTOR, or bankruptcy, reorganization, arrangement or insolvency proceedings, or other proceedings for relief under any bankruptcy or similar law or laws for the relief of debtors, are instituted by or against CONTRACTOR, and in any of the foregoing cases such action is not discharged or terminated within sixty (60) Days of its institution.

12.2 Remedies of CITY upon a CONTRACTOR Event of Default.

12.2.1 Termination of Contract. Upon the occurrence of a CONTRACTOR Event of Default, CITY shall have the right to terminate this Contract upon an additional seven (7) Days written notice to CONTRACTOR, provided that CONTRACTOR has not commenced a cure within such seven (7) Day period. Without prejudice to any other rights or remedies of CITY, CITY may:

39 [3/21/25]

12.2.1.1 Take possession of the Site and of all materials, equipment, tools and construction equipment thereon owned by CONTRACTOR, excluding equipment, tools and construction equipment owned by Contractor’s subcontractors.

12.2.1.2 Accept assignment of Subcontracts; and

12.2.1.3 Finish the Work by whatever reasonable method CITY may deem expedient.

12.2.1.4 When CITY terminates the Contract as aforesaid, CONTRACTOR shall not be entitled to receive further payment until the Work is finished. If the unpaid balance of the GMP exceeds costs incurred in finishing the Work, such excess shall be paid to CONTRACTOR, up to the amount due CONTRACTOR for work performed prior to termination. If such costs exceed the unpaid balance of the GMP, CONTRACTOR shall pay the difference to CITY.

12.2.2 Recourse to Payment and Performance Bonds. Upon the occurrence of a CONTRACTOR Event of Default and termination of this Contract by CITY, CITY may call upon the Surety to perform its/their obligations under the Payment and Performance Bonds, if applicable.

12.3 Remedies not Exclusive. Except as otherwise provided in this Agreement, no remedy hereunder is intended to be exclusive of any other remedy, but each and every such remedy shall be cumulative and shall be in addition to any other available legal or equitable remedy, existing now or hereafter. No delay or omission to exercise any right or power accruing shall impair any such right or power nor shall it be construed to be a waiver of any Event of Default or acquiescence therein, and every such right and power may be exercised from time to time as often as may be deemed expedient.

12.4 Termination or Suspension for Convenience.

12.4.1 Termination for Convenience. CITY may, without cause, terminate this Contract, or any portion of Work to be performed hereunder at any time by a notice in writing from CITY to CONTRACTOR for CITY's convenience. In such case, CITY shall pay to CONTRACTOR all funds due CONTRACTOR for work performed up to the date of termination, plus all demobilization and close-out costs, including, but not limited to, any amounts payable to Subcontractors for early termination, plus reasonable overhead and profit on Work performed. All funds due hereunder, including unpaid Retention, shall be released within thirty (30) Days of termination of the Contract for convenience, subject to any withholding required or authorized by any Applicable Law. In no event shall such amounts owed to CONTRACTOR exceed the GMP.

12.4.2 Suspension for Convenience. CITY may, without cause, order CONTRACTOR in writing to suspend, delay or interrupt the Work in whole or in part for such period of time as CITY may determine. An adjustment shall be made for increases in the cost of performance of the Work, including Fee on the increased cost of performance, caused by the suspension, delay 40 [3/21/25]

or interruption, in accordance with the Change Order provisions of this Contract. No adjustment shall be made to the extent (1) the performance is, was or would have been so suspended, delayed or interrupted by another cause for which CONTRACTOR is responsible or (2) that an equitable adjustment to the GMP and/or Schedule is made or denied under another provision of this Contract. Adjustments made in the cost of performance may have a mutually agreed fixed or percentage Fee.

ARTICLE 13

MISCELLANEOUS PROVISIONS

13.1 Governing Law. This Contract shall be construed with and governed by the laws of the State of California.

13.2 Successors and Assigns. CITY and CONTRACTOR respectively bind themselves, their partners, shareholders, successors, assigns and legal representatives to the other Party hereto and to shareholders, successors, assigns and legal representatives of such other Party in respect to covenants, agreements and obligations contained in the Contract Documents. Neither Party shall assign the Contract without the prior written consent of the other.

13.3 Notice. Any notices to Parties required by this Agreement shall be delivered or mailed, U.S. first class, postage prepaid, addressed as follows:

If to CITY: If to CONTRACTOR:

Electric Department IEC Corporation
Ozro Corulli Eric Quintero, President
2090 Hilltop Circle 3100 Zinfandel Dr., Suite 350
Roseville, CA 95747 Rancho Cordova, CA 95670

Address for Notice may be changed by Notice to the other Party.

13.4 Prevailing Wages. For purposes of this Agreement, CONTRACTOR and its Subcontractors shall comply with all applicable prevailing wage laws, e.g., but not limited to, California Labor Code Sections 1770 et seq. In accordance with said Section 1775, CONTRACTOR shall forfeit as a penalty to CITY Two Hundred Dollars ($200) for each calendar Day or portion thereof for each worker paid less than the prevailing rates for such work or craft in which such worker is employed for any work done on-Site under the Agreement by CONTRACTOR or by any Subcontractor in violation of the provisions of the Labor Code and in particular, Labor Code Sections 1770 to 1780, inclusive. In addition to said penalty and pursuant to said Section 1775, the difference between such stipulated prevailing wage rates and the amount paid to each worker for each calendar Day or portion thereof for which each worker was paid less than the stipulated prevailing wage shall be paid to each worker by CONTRACTOR or the applicable Subcontractor.

41 [3/21/25]

Pursuant to the provisions of California Labor Code Section 1773, the Department of Industrial Relations has identified the source, stated below, of the General Prevailing Rate of Wages applicable to the work to be done, for straight time, overtime, and holiday work. The holiday wage rate listed shall be applicable to all holidays recognized in the collective bargaining agreement of the particular craft, classification or type of worker concerned. These wage rates may be obtained from the State Department of Industrial Relations and/or the following website address: http://www.dir.ca.gov/dlsr/DPreWageDetermination.htm, which is a part of this Agreement.

Pursuant to Labor Code Section 1773.2, the General Prevailing Wage Rates set forth above by the Department of Industrial Relations, which form a part of this Agreement, shall be posted by CONTRACTOR at a prominent place at the Site.

13.5 Modifications. No Modifications or Change Orders shall be valid unless in writing and signed by CITY and CONTRACTOR.

13.6 Interpretation. Any and all headings of this Agreement are for convenience of reference only and do not modify, define or limit the provisions thereof. Words of any gender shall be deemed and construed to include correlative words of the other gender. Words importing the singular number shall include the plural number and vice versa, unless the context shall otherwise be deemed to include all supplements and/or amendments to any such exhibits or documents entered into in accordance with the terms hereof and thereof. All references to any person or entity shall be deemed to include any person or entity succeeding to the rights, duties and obligations of such person or entity in accordance with the terms of this Agreement. Where reference is made in this Agreement to another Contract Document, the reference refers to that provision as amended or supplemented by the other provisions of the Contract Documents. In the event of any conflict between or among the Contract Documents, the provisions of this Agreement shall govern.

13.7 Severability. If any provision of this Agreement is held to be inoperative or unenforceable as applied in any particular case because it conflicts with any other provision hereof or any constitution, statute, ordinance, rule of law or public policy, or for any other reason, such holding shall not have the effect of rendering the provision in question inoperative or unenforceable in any other case, or of rendering any other provision herein contained inoperative or unenforceable to any extent whatever. The invalidity of any one or more phrases, sentences, clauses or sections contained in this Agreement shall not affect the remaining portions of this Agreement or any part hereof, and they shall otherwise remain in full force and effect.

13.8 Whole Agreement. This Agreement, the Exhibits hereto and the Contract Documents, specifications and Drawings shall constitute the entire agreement between the Parties, and no inducements, considerations, promises or other references shall be implied in this Agreement that are not expressly addressed herein

13.9 Accounting Records. CONTRACTOR shall keep full and detailed accounts and exercise such controls as may be necessary for proper financial management under this Agreement; the accounting and control systems shall be reasonably satisfactory to CITY. CITY and CITY's accountants shall be afforded access to CONTRACTOR's records, books, 42 [3/21/25]

correspondence, instructions, drawings, receipts, Subcontracts, vouchers, memoranda and other data relating to this Agreement, and CONTRACTOR shall preserve these for a period of three (3) years after final payment, or for such longer period as may be required by law.

13.10 Intentionally left blank.

13.11 No Waiver. Neither the inspection by CITY or its agents, nor any order or certificate for payment of money, nor payment for, nor acceptance of the whole or any part of the work by CITY, nor any extensions of time, nor any position taken by CITY or its agents shall operate as a waiver of any provision of this Agreement or of any power herein reserved to CITY or any right to damages herein provided, nor shall any waiver of any breach of this Agreement be held to be a waiver of any other or subsequent breach. CONTRACTOR’s waiver of any breach hereof shall not constitute a waiver of any subsequent breach of the same or any other provision hereof.

13.12 CONTRACTOR Shall Assume Risks. Until the Final Completion or acceptance by CITY of all Work under this Contract, the Work shall be under CONTRACTOR's responsible care and charge. CONTRACTOR shall rebuild, repair, restore and make good all injuries, damages, corrections, and repairs occasioned or rendered necessary by accidental causes of any nature, to all or any portions of the Work, except as otherwise stipulated.

13.13 General Liability of CONTRACTOR. Except as otherwise herein expressly stipulated, CONTRACTOR shall perform all the work and furnish all the labor, materials, tools power and light, and appliances, necessary or proper for performing and completing the Work herein required in the manner within the time herein specified. The mention of any specific duty or liability of CONTRACTOR shall not be construed as a limitation or restriction of any general liability or duty of CONTRACTOR and, any reference to any specific duty or liability shall be construed to be the purpose of explanation.

13.14 Attorney’s Fees and Venue. If either Party commences any legal action against the other Party arising out of this Agreement or the performance thereof, the prevailing Party shall be entitled to recover its reasonable litigation expenses, including but not limited to, court costs, expert witness fees, discovery expenses, and attorney’s fees. Any action arising out of this Agreement shall be brought in Placer County, California, regardless of where else venue may lie.

To the extent permitted by applicable law, each Party waives any defense that it may have based on lack of in personam jurisdiction or forum nonconveniens.

13.15 Third Party Beneficiaries. There are no third party beneficiaries to this Agreement.

IN WITNESS WHEREOF, the City of Roseville, a municipal corporation, has authorized the execution of this Agreement in duplicate by its City Manager and attested to by its City Clerk under the authority of Resolution No. ______, adopted by the Council of the City of Roseville on the ___ day of ____________, 20___, and CONTRACTOR has caused this Agreement to be executed.

[3/21/2025]
LIST OF EXHIBITS:

Exhibit A Guaranteed Maximum Price

Exhibit B Construction Allowance Items [reserved]

Exhibit C Hazardous Materials

Exhibit D In Lieu of Securities Escrow Agreement

Exhibit E Performance, Labor & Materials, and Warranty Bonds (Note: Warranty Bond may be waived at the option of CITY)

Exhibit F CONTRACTOR’s Proposal

1 [3/21/2025]

EXHIBIT A

GUARANTEED MAXIMUM PRICE, FEE, AND COST OF WORK

A. GUARANTEED MAXIMUM PRICE: The Guaranteed Maximum Price as of the date of execution of this Agreement is thirty-eight million, eight hundred thirty-five thousand, nine hundred and twenty-five dollars ($38,835,925), U.S. Currency.

B. FEE AND CONTINGENCY: The Fee and Contingency amounts, if any, are as stated in the Proposal.

C. COST OF THE WORK:

1. "Cost of the Work." The term "Cost of the Work" shall mean costs incurred by CONTRACTOR in the performance of the Work, that do not exceed the GMP. The following are categories of cost and expense to be paid by CITY to CONTRACTOR as Cost of the Work:

2. Construction Costs.

2.1 Labor Costs.

2.1.1 Wages of construction workers directly employed by CONTRACTOR to perform the construction of the Work at the Site or, with CITY's agreement, at off-site workshops.

2.1.2 Wages or salaries of CONTRACTOR's supervisory and administrative personnel when stationed at the Site and wages, salaries and other costs of project management, pre-construction services, form design, foundation engineering, manpower planning, purchasing, estimating and data processing, whether performed at the Site or in CONTRACTOR's offices, including, but not limited to services rendered during the Design Phase of the Project.

2.1.3 Wages and salaries of CONTRACTOR's supervisory or administrative personnel engaged at factories, workshops or on the road, in expediting the production or transportation of materials or equipment required for the Work, but only for that portion of their time required for the Work.

2.1.4 Costs paid or incurred by CONTRACTOR for taxes, insurance, contributions, assessments and benefits required by law or collective bargaining agreements and, for personnel not covered by such agreements, customary benefits such as sick leave, medical and health benefits, holidays, vacations and pensions, provided such costs are based on wages and salaries included in subsections 2.1.1 through 2.1.3 above.

2.2 Subcontract Costs. Amounts due Subcontractors for work, excluding Change Order work, in accordance with the requirements of the Subcontracts.

2 [3/21/2025]

2.3 Costs of Materials and Equipment Incorporated in the Completed Construction. Costs, including transportation, of materials and equipment incorporated or to be incorporated in the completed construction.

2.4 Costs of other Materials and Equipment, Temporary Facilities, and Related Items.

2.4.1 Costs, including transportation, installation, maintenance, dismantling and removal of materials, supplies, temporary facilities, machinery, equipment and hand tools not customarily owned by the construction workers, which are provided by CONTRACTOR at the Site and fully consumed in the performance of the Work; and cost, less salvage value, on such items if not fully consumed, whether sold to others or retained by CONTRACTOR. Costs for items previously used by CONTRACTOR shall mean fair market value.

2.4.2 Rental charges for temporary facilities, machinery, equipment and hand tools not customarily owned by the construction workers, which are provided by CONTRACTOR at the Site, whether rented from CONTRACTOR or others, and costs of transportation, installation, minor repairs and replacements, dismantling and removal thereof.

Rental charges for equipment owned by CONTRACTOR shall be at then prevailing rates.

2.4.3 Costs of removal of debris from the Site.

2.4.4 Costs of facsimiles, telegrams and long distance telephone calls, postage and delivery charges (whether originating at the Site or at the offices of CONTRACTOR or CONTRACTOR), telephone service at the Site and reasonable petty cash expenses of the Site office.

2.5 Premiums; Taxes; Fees; Royalties.

2.5.1 That portion directly attributable to this Agreement of premiums for insurance and the Payment and Performance Bonds.

2.5.2 Sales, use, gross receipts or similar taxes imposed by a governmental authority, which are related to the Work and for which CONTRACTOR is liable.

2.5.3 Fees and assessments for any permits, licenses and inspections required by the Contract Documents.

2.5.4 Fees of testing laboratories for tests required by the Contract Documents or government authorities.

2.5.5 Royalties and license fees paid for the use of a particular design, process or product required by the Contract Documents. The costs of defending suits or claims for infringement of patent rights arising from such requirement by the Contract Documents; payments made in accordance with legal judgments against CONTRACTOR or CONTRACTOR resulting from such suits or claims and payments of settlements in connection therewith. 3 [3/21/2025]

2.5.6 Deposits lost for cause other than CONTRACTOR's negligence.

2.6 Emergencies. Costs incurred in taking action to prevent threatened damage, injury or loss in case of emergency affecting the safety of persons and property, as provided in Section 10.7 of this Agreement.

2.7 Other Costs. Other costs incurred in the performance of the Work, if and to the extent approved in writing by CITY, which approval shall not be unreasonably withheld.

3. Items not Included in Cost of the Work.

3.1 Salaries and other compensation of CONTRACTOR's personnel stationed at CONTRACTOR's principal office or offices other than the Site, except as specifically provided in subsections 2.1.2 and 2.1.3 above.

3.2 Expenses of CONTRACTOR's principal office and offices, other than the Site office.

3.3 Overhead and general expenses, except as may be included in Sections 1 and 2 above.

3.4 The capital expenses of CONTRACTOR, including interest on capital employed for the Work.

3.5 Costs that would cause the GMP to be exceeded.
[H:\09- DISTRIBUTION\engineer\RPP2\RFP Documents\Proposals\Design Build Agreement_Award.docx; 3/21/25]

EXHIBIT B

CONSTRUCTION ALLOWANCE ITEMS

(reserved)

1 [3/21/2025]

EXHIBIT C

HAZARDOUS MATERIALS

1. Certain Definitions.

1.1 "Hazardous Materials means any substance:

1.1.1 the presence of which requires investigation or remediation under federal, state or local law, statute, regulation, ordinance, order, action, policy or common law;

1.1.2 which is or becomes defined as a "hazardous waste," "hazardous substance," pollutant or contaminant under any federal, state or local law, statute, regulation, rule or ordinance or amendments thereto, including, without limitation, the Comprehensive Environmental Response, Compensation and Liability Act, 42 USC §§9601 et seq. ("CERCLA"), as amended, or the Resource, Conservation and Recovery Act, as amended, 42 USC §§6901 et seq. ("RCRA");

1.1.3 which is petroleum, including crude oil or any fraction thereof not otherwise designated as a "hazardous substance" under CERCLA, including without limitation gasoline, diesel fuel or other petroleum hydrocarbons;

1.1.4 which is toxic, explosive, corrosive, flammable, infectious, radioactive, carcinogenic, mutagenic, or otherwise hazardous and is or becomes regulated by any governmental authority or instrumentality;

1.1.5 the presence of which on the Site causes or threatens to cause a nuisance upon the Site or to the adjacent properties or poses or threatens to pose a hazard to the health or safety of persons on or about the Site; or

1.1.6 the presence of which on adjacent properties could constitute a trespass by CONTRACTOR or CITY.

1.2 "Underground Storage Tank" shall have the definition assigned to that term by RCRA §9001, 42 USC §6991, and also shall include:

1.2.1 any tank of 1,100 gallons or less capacity used for storing motor fuel;

1.2.2 any tank used for storing heating oil for consumption on the premises where stored;

1.2.3 any septic tank; and

1.2.4 any pipes connected to items 1.2.1-1.2.3.

2 [3/21/2025]

1.3 "Environmental Requirements" means all Applicable Laws, statutes, regulations, rules, ordinances, codes, licenses, permits, orders and similar items of all federal, state or local governmental agencies or other instrumentalities and all applicable judicial, administrative and regulatory decrees, judgments and orders relating to the protection of human health or the environment, including, without limitation:

1.3.1 all requirements, including but not limited to, those pertaining to reporting, licensing, permitting, investigation and remediation of emissions, discharges, releases or threatened releases of Hazardous Materials into the air, surface water, ground water or land, or relating to the manufacture, processing, distribution, use, treatment, storage, disposal, transport or handling of Hazardous Materials; and

1.3.2 all requirements pertaining to the protection of the health and safety of employees or the public.

1.4 "Environmental Damages" means all claims, judgments, damages, losses, penalties, fines, liabilities, encumbrances, liens, costs and expenses of investigation and defense of any claim, including, without limitation, attorney's fees, which are incurred at any time as a result of the existence of Hazardous Materials upon, about or beneath the Site or migrating or threatening to migrate to or from the Site, and including, without limitation:

1.4.1 damages for personal injury, or injury to property or to natural resources occurring upon or off the Site;

1.4.2 fees incurred for the services of attorneys, consultants, CONTRACTOR, experts, laboratories and all other costs incurred in connection with the investigation or remediation of such Hazardous Materials or violation of Environmental Requirements; and

1.4.3 liability to any third party or governmental agency or political subdivision to indemnify such party, agency or political subdivision for costs expended in connection with the items listed in subparagraph 1.4.2.

1.5 "Environmental Conditions" means collectively, Hazardous Materials and Underground Storage Tanks existing on the Site and not brought there by CONTRACTOR or any Subcontractor.

2. Investigation of Site.

2.1 Upon written notice from CITY, CONTRACTOR shall prepare for approval and execution by CITY, one or more contracts ("Environmental Contracts") with suitably qualified consultants and/or engineers ("Environmental Engineers"), for purposes of performing an investigation and analysis of the Site prior to demolition and excavation activities, to determine the presence of any Environmental Conditions on, in or under the Site. The Environmental Contracts shall provide for a commercially reasonable scope of investigation approved by CITY, and may provide for conducting the investigation and testing in phases acceptable to CITY. The Environmental Contracts shall also provide that the Environmental Engineers shall begin their

3 [3/21/2025]
tests and inspections at the Site as soon as CITY is able to arrange access to the Site, or any portions thereof, for such purposes. The Environmental Contracts shall provide that CONTRACTOR, acting as agent of CITY, shall coordinate the activities of the Environmental Engineers.

2.2 The Environmental Contracts shall provide that the Environmental Engineers shall prepare such reports, feasibility studies and remedial plans ("Environmental Assessments") as may be reasonably necessary in order to identify and explain the quantity, scope and nature of the Environmental Conditions found to exist at the Site. The Environmental Assessments shall contain a detailed analysis of the Environmental Conditions discovered, and the actions ("Remedial Actions") required for the response, removal, cleanup or remediation of such Environmental Conditions (i) which are required by Environmental Requirements, or (ii) which are reasonably necessary to mitigate Environmental Damages.

2.3 The Environmental Contracts shall provide that the Environmental Engineers shall promptly provide CITY and CONTRACTOR with a copy of each Environmental Assessment, together with any other reports and test results generated pursuant to the Environmental Contracts. CONTRACTOR shall, promptly after receipt of the foregoing matters from the Environmental Engineers, prepare and submit to CITY a written report setting forth CONTRACTOR's understanding of whether and to what extent any recommended Remedial Actions may result in an amendment to the Schedule and the progress of the Work.

2.4 The Environmental Contracts shall provide that it shall be the responsibility of the Environmental Engineers to give any necessary notice to the appropriate regulatory agency or agencies of the presence of any Environmental Conditions; to pursue all necessary negotiations with such agencies concerning preparation and approval of a plan for clean-up to the extent required; and to obtain all necessary permits to perform any Remedial Actions.

3. Remedial Actions.

3.1 If so instructed by CITY, based upon the results of the Environmental Assessments, CONTRACTOR shall, as agent for CITY, obtain bids from remediation contractors ("Remediation Contractors) suitably qualified and approved by CITY, to perform the Remedial Actions selected by CITY and shall submit such bids to CITY, together with CONTRACTOR's recommendation of the Remediation Contractor(s) to be retained. If CITY elects to go forward with all or any portion of the Remedial Actions covered by the bids submitted, CITY will so advise CONTRACTOR in a written notice on or before the date which is sixty (60) Days after receipt of the foregoing matters from CONTRACTOR. Promptly after receipt of such notice, CONTRACTOR shall prepare for CITY's execution remediation contracts ("Remediation Contracts") with the Remediation Contractors identified in such notice.

3.2 CONTRACTOR, as agent for CITY, shall be responsible for coordinating the work and services performed by the Remediation Contractors, and coordinating such remediation work with the Work.

4 [3/21/2025]

3.3 If in the course of performance of the Work, CONTRACTOR encounters on the Site any Hazardous Materials not previously disclosed and remediated by the Environmental Engineers or the Remediation Contractors, CONTRACTOR shall immediately suspend the Work in the area affected and promptly thereafter report the condition to CITY.

4. Payments: Liability of CONTRACTOR.

4.1 All payments due under the Environmental Contracts and the Remediation Contracts shall be made by CITY directly to the Environmental Engineers and the Remediation Contractors. Such payments will be based on requisitions, which requisitions shall be approved by CONTRACTOR prior to submission to CITY.

4.2 All payments due under the Environmental Contracts, the Remediation Contracts and for Environmental Damages, shall not be a part of the GMP, and shall be the sole responsibility of CITY, except as expressly provided otherwise in Section 5 hereof.

4.3 It is understood and agreed that with respect to any Environmental Conditions existing on the Site, CONTRACTOR is not, and shall not be deemed to be, a generator, arranger, operator, treater, storer, transporter or disposer of, or otherwise responsible for, any such Environmental Conditions. It is understood and agreed that CONTRACTOR shall have no right to direct the means or methods of performance of any Environmental Engineer or Remediation Contractor.

4.4 CITY shall indemnify, defend and hold harmless CONTRACTOR, from and against any Environmental Damages asserted against or sustained by CONTRACTOR as a result of CONTRACTOR being deemed or determined to be a generator, arranger, operator, treater, storer, transporter or disposer of, or otherwise responsible for, any such Environmental Conditions.

5. Environmental Responsibilities of CONTRACTOR.

5.1 CITY acknowledges and agrees that CONTRACTOR shall not commence or continue any demolition or construction activities on any portion of the Site on or in which Remedial Actions are to be performed until such Remedial Actions are to the point where construction activities will not interfere with such Remedial Actions, as evidenced by appropriate certification by the applicable Environmental Engineer and/or Remediation CONTRACTOR and any required approval of any applicable government agency.

CONTRACTOR agrees to use good faith diligent efforts to adjust and reschedule its activities at the Site so as to minimize, to the extent reasonably practical, the adverse effect on the progress of the Work resulting from any Remedial Actions.

5.2 CONTRACTOR shall not bring Hazardous Materials to the Site, and shall not include Hazardous Materials in any construction materials, unless permitted by Environmental Requirements. CONTRACTOR shall comply, and shall cause all Subcontractors to comply, with all Environmental Requirements regarding the generation, handling, storage, treatment and disposal of Hazardous Materials.

5 [3/21/2025]

5.3 CONTRACTOR shall indemnify, defend and hold harmless the Indemnified Parties from and against any Environmental Damages asserted against or sustained by such parties as a result of any Environmental Conditions caused or created by CONTRACTOR or any Subcontractor, or of any violation by CONTRACTOR or the Subcontractors, of any Environmental Requirement arising out of the performance of the Work.

[H:\09- DISTRIBUTION\engineer\RPP2\RFP Documents\Proposals\Design Build Agreement_Award.docx; 3/21/25]

EXHIBIT D

IN LIEU OF SECURITIES ESCROW AGREEMENT

(form of agreement follows this page)
(use is optional by Contractor)

ESCROW No. ___________
03/21/2025]

ESCROW AGREEMENT FOR SECURITY DEPOSITS IN LIEU OF RETENTION (Project: ________________________________________)

THIS ESCROW AGREEMENT is made and entered into on this ____ day of _________________, 20__ by and between the:

City of Roseville, whose address is:
311 Vernon Street
Roseville, CA 95678
(hereinafter called "CITY"); and
________________________________, whose address is:
________________________________
________________________________
(hereinafter called "CONTRACTOR"); and
________________________________, whose address is:
________________________________
________________________________
(hereinafter called “ESCROW AGENT”).

For the consideration hereinafter set forth, CITY, CONTRACTOR, and ESCROW AGENT agree as follows:

1. Pursuant to Section 22300 of the Public Contract Code of the State of California, CONTRACTOR has the option to deposit securities, subject to prior approval of CITY, with ESCROW AGENT, as a substitute for retention earnings required to be withheld by CITY pursuant to the contract for public works entered into between the CITY and CONTRACTOR for the Project in the amount of __________________________________________________

2 [3/21/25]
__________________ dollars ($__________) dated _____________________, (hereinafter referred to as the “Contract”). Alternatively, on written request of CONTRACTOR, CITY shall make payments of the retention earnings directly to the ESCROW AGENT.

When CONTRACTOR deposits the securities as a substitute for Contract earnings, the ESCROW AGENT shall notify CITY within ten (10) days of the deposit. The market value of the securities at the time of the substitution shall be at least equal to the cash amount then required to be withheld as retention under the terms of the Contract between CITY and CONTRACTOR. Securities shall be held in the name of ESCROW AGENT, and shall designate CONTRACTOR as the beneficial owner, and shall be limited to those types of acceptable securities as described in Public Contract Code Section 22300.

2. CITY shall make progress payments to CONTRACTOR for those funds which otherwise would be withheld from progress payments pursuant to the Contract provisions, provided that ESCROW AGENT holds securities in the form and amount specified above.

3. When CITY makes payment of retentions earned directly to ESCROW AGENT, ESCROW AGENT shall hold them for the benefit of CONTRACTOR until the time that the escrow created under this Agreement is terminated. CONTRACTOR may direct the investment of the payments into securities. All terms and conditions of this Agreement and the rights and responsibilities of the parties shall be equally applicable and binding when CITY pays ESCROW AGENT directly.

4. CONTRACTOR shall be responsible for paying all fees for the expenses incurred by ESCROW AGENT in administering the Escrow Account and all expenses of CITY. These expenses and payment terms shall be determined by CITY, CONTRACTOR, and ESCROW AGENT.

3 [3/21/25]

5. The interest earned on the securities or the money market accounts held in escrow and all interest earning on that interest shall be for the sole account of CONTRACTOR and shall be subject to withdrawal by CONTRACTOR at any time and from time to time without notice to CITY.

6. CONTRACTOR shall have the right to withdraw all or any part of the principal in the Escrow Account only by written notice to ESCROW AGENT accompanied by written authorization from CITY to ESCROW AGENT that CITY consents to the withdrawal of the amount sought to be withdrawn by CONTRACTOR.

7. CITY shall have a right to draw upon the securities in the event of default by CONTRACTOR. Upon seven (7) days’ written notice to ESCROW AGENT from CITY of the default, ESCROW AGENT shall immediately convert the securities to cash and shall distribute the cash as instructed by CITY.

8. Only upon receipt of written notification from CITY certifying that the Contract is final and complete, and that CONTRACTOR has complied with all requirements and procedures applicable to the Contract, ESCROW AGENT shall release to CONTRACTOR all securities and interest on deposit less escrow fees and charges of the Escrow Account. The escrow shall be closed immediately upon disbursement of all moneys and securities on deposit and payments of fees and charges.

9. ESCROW AGENT shall rely on the written notifications from CITY and CONTRACTOR pursuant to Sections (5) to (8), inclusive, of this Agreement and CONTRACTOR shall hold ESCROW AGENT harmless from ESCROW AGENT’s release and disbursement of the securities and interest as set forth above.

4 [3/21/25]

10. The parties hereto mutually agree that this Agreement is substantially similar to the form under Public Contracts Code Section 22300.

11. The names of the persons who are authorized to give written notice or to receive written notice on behalf of CITY and on behalf of CONTRACTOR in connection with the foregoing, and exemplars of their respective signatures are as follows:

On behalf of CITY:
____________________________________
Title
____________________________________
Name
____________________________________
Signature
____________________________________
Address

On behalf of CONTRACTOR:

____________________________________
Title
____________________________________
Name
____________________________________
Signature
____________________________________
Address

On behalf of ESCROW AGENT:

____________________________________
Title
____________________________________
Name
____________________________________
Signature
____________________________________
Address

12. At the time the Escrow Account is opened, CITY and CONTRACTOR shall deliver to ESCROW AGENT a fully executed counterpart of this Agreement.

5 [3/21/25]
IN WITNESS WHEREOF, the City of Roseville, a municipal corporation, has authorized the execution of this Agreement by its City Manager and attestation by its City Clerk under the authority of Resolution No. 87-141, adopted by the Council of the City of Roseville on the 5th day of August, 1987, and CONTRACTOR and ESCROW AGENT have authorized the execution of this Agreement.

CITY OF ROSEVILLE, a CONTRACTOR:
municipal corporation: ________________________________, a _________________________________

BY:______________________________ BY:__________________________

DOMINICK CASEY
City Manager its:___________________________

and
ATTEST:

BY:__________________________

BY:______________________________ its:___________________________

CARMEN AVALOS
City Clerk
ESCROW AGENT:

BY:__________________________
APPROVED AS TO FORM:
its:___________________________

BY:______________________________ and

MICHELLE SHEIDENBERGER
City Attorney BY:__________________________

its:___________________________
APPROVED AS TO SUBSTANCE:

BY:______________________________

DENNIS KAUFFMAN
Assistant City Manager/Chief Financial Officer

6 [3/21/25]

ACKNOWLEDGED BY ADMINISTERING DEPARTMENT:

BY: ______________________________

03/21/2025]

EXHIBIT E

BOND FORMS

03/21/2025]

EXHIBIT F

CONTRACTOR’S PROPOSAL
RESOLUTION NO. 25-084

APPROVING A DESIGN-BUILD CONSTRUCTION AGREEMENT, BY AND BETWEEN

INTEGRATED ENGINEERS AND CONTRACTORS CORPORATION DBA IEC

CORPORATION AND THE CITY OF ROSEVILLE, AND AUTHORIZING THE CITY

MANAGER TO EXECUTE IT ON BEHALF OF THE CITY OF ROSEVILLE

WHEREAS, a Design-Build Construction Agreement for the Roseville Power Plant #2 Repower project, by and between Integrated Engineers and Contractors Corporation dba IEC Corporation and the City of Roseville, has been reviewed by the City Council; and

NOW, THEREFORE, BE IT RESOLVED by the Council of the City of Roseville that said agreement is hereby approved.

BE IT FURTHER RESOLVED that the City Manager or his designee is authorized to approve change orders for the project, consistent with the contract terms, provided that the net cost of all change orders shall not exceed five percent (5%) of the contract price.

PASSED AND ADOPTED by the Council of the City of Roseville this ___ day of ______________, 20__, by the following vote on roll call:

AYES COUNCILMEMBERS:

NOES COUNCILMEMBERS:

ABSENT COUNCILMEMBERS:

______________________________
MAYOR

ATTEST:

________________________
City Clerk

SUBMITTE D TO:

City of Roseville
Attn: City Clerk Department
311 Vernon Street
Roseville, CA 95678
SUBMITTE D TO:

City of Roseville
Attn: City Clerk Department
311 Vernon Street
Roseville, CA 95678
SUBMITT ED BY:

TRUSTED TEAM
IEC Corporation
3100 Zinfandel Dr., Suite 350
Rancho Cordova, CA 95670
Phone: 916.383.6000
Website: iec-corporation.com
JANUARY 30, 2025

PROPOSA L FOR T HE CIT Y OF R OSEVI LLE

DESIGN AND CONSTRUCTION SERVICES FOR
ROSEVILLE POWER PLANT #2 REPOWER
RFP #07-109

A. Cover Letter
A. B. Firm's Qualifications
B. C. Experience and References
C. D. Qualifications of Team
D. E. Project Understanding
E. F. Project Plan
F. G. Cost Proposal
G. H. Required Statements/Documents
H. I. Exceptions
I. J. Competency of Proposer
J. K. Safety Record
Appendix A – Resumes

SECTION A

FIRM'S QUALIFICATIONS
A-1

SECTION A

FIRM'S QUALIFICATIONS
A-2
A. FIRM'S QUALIFICATIONS

Turnkey Services for the RPP2 Repower Project

The City of Roseville (City) requires comprehensive turnkey services for the RPP2 Repower Project. The ideal partner must demonstrate:

1. Proven engineering and design expertise

2. Direct construction experience with Roseville power plants

3. Flexibility to execute work in accordance with City policies, procedures, and schedule

IEC and our project team are uniquely positioned to meet and exceed these requirements.

Our team comprises well-established companies that have successfully supported the City for years in operations, maintenance, and capital projects at RPP2, REP, and RPEAK. Our extensive experience spans engineering, design, mechanical and electrical construction, controls upgrades, permitting, and a wide range of plant improvement initiatives.

Our deep understanding of the City’s standards, policies, and procedures—combined with our proven track record of collaborating closely with plant staff to deliver projects on time and within budget—is unmatched by any other team.

Team Qualifications Overview

This section outlines our team’s qualifications and includes the following subsections:

• A1. IEC Qualifications Overview: About IEC Corporation • A2. IEC Letters of Recommendation
• A3. Subcontractor Overview and Project Organization Chart • A4. Subcontractor Qualification Bios
• A5. IEC Team Added Value
• A6. Letter of Bondability

SECTION A

FIRM'S QUALIFICATIONS
A-3
A1. About IEC Corporation
IEC Corporation is a multi-discipline engineering, design, and construction management firm headquartered in
Sacramento, California. We specialize in providing
professional services to utilities, supporting the design, expansion, modification, and upgrade of power
generation facilities and power delivery systems. Our
comprehensive expertise spans the entire project
lifecycle—from feasibility studies and preliminary
engineering to design, construction, and operations.

Our team includes a diverse group of licensed
California professional engineers and construction
management experts across all disciplines including
electrical, controls, mechanical, civil, and structural.

With extensive experience in both engineering and
construction, we are well-equipped to handle complex,
multi-discipline infrastructure projects of any scale.

Expertise in Power Generation and Delivery
IEC brings extensive experience in the design and
implementation of power generation and delivery
projects, with a particular focus on serving public
agencies and utilities. We understand the rigorous
standards and robust design requirements that public
entities demand to meet long -term operational goals
and accountability. Our field -tested designs align with the strin gent reliability, maintenance, liability
protection, and long- term return -on-investment
expectations of our clients.

Commitment to Quality and Responsiveness
IEC has earned a strong reputation for delivering high- quality engineering and turnkey construction services to California’s public agencies. Our commitment to excellence and responsiveness has positioned us as a trusted partner in the industry. We encourage the City to contact our references, as outlined in Section B, to gain further insight into our proven track record and unwavering dedication to client success.

IEC CORPORATION
"Shaping the Future of Energy"
Headquarters Office: Sacramento, CA
Website: iec-corporation.com
Year established: 2000
Size: 30+ Employees and Consultants
Licenses:
• A - General Engineering #786949
• C-10 Electrical Engineering #786949
• CA Electrical Engineers
• CA Mechanical Engineers
• CA Structural Engineers
• CA Civil Engineers
Public Agency Expertise: Similar generation
engineering contract work for SMUD, TID,
MID, SDG&E, LADWP, NCPA, and AML&P,
among other clients.

Master Services Contracts: More than 50
public agency contracts in the past decade.

IEC becomes much more than just a
contractor, but rather an important
partner in the successful completion of the
project. This perspective means we see the
project from the viewpoint of the City and
will ensure that the RPP2 Repower Project
exceeds City expectations.

SECTION A

FIRM'S QUALIFICATIONS
A-4
A2. Letters of Recommendation
As evidence of our commitment to excellence, IEC has included letters of recommendation at the end of this section . The testimonials highlight IEC’s continuous and consistent commitment to providing the highest level of expertise and responsiveness. This level of service is what the City of Roseville can expect from IEC for the RPP2 Repower Project.

A3. Subcontractor Overview and Project Organization Chart IEC Corporation is complemented by a resource of proven subcontractors and industry experts (IEC Team).

To maximize the quality of our services specific to the RPP2 Repower Project, IEC Corporation has formed an exclusive team who are intimately familiar with Roseville generation resources. These trusted partners include:

Professional Services
• Verve Industrial Protection
• REY Engineers Inc.
• Youngdahl Consulting Group, Inc.
• Trinity Consultants
• Power Systems Testing Co.

Construction Services
• Performance Mechanical, Inc.
• Placer Electric, Inc.
• Western States Fire Protection
• Superior Tank

Major Equipment Vendors
• General Electric
• Compass
• Cemtek
• Teledyne
• Eaton
• Siemens
• Ritz Usa
• Ecologix
• Envirogen Technologies

Project Organization Chart – The next page illustrates the project team structure and each of their roles for the project.

SECTION A

FIRM'S QUALIFICATIONS
A-5

SECTION A

FIRM'S QUALIFICATIONS
A-6
A4. Subcontractor Qualification Bios
To demonstrate the capabilities of our Team, a brief introduction to each team member is provided below.

Performance Mechanical, Inc (PMI)
Performance Mechanical, Inc. (PMI) is a premiere specialty union industrial contractor primarily servicing the Power, Petrochemical, and Food and Beverage industries
throughout California, with annual revenues ranging from $100-140M annually. PMI was purchased by EMCOR in
2008. The acquisition provided financial strength and
backing for significant growth. As the largest specialty mechanical and electrical contractor in the United States, EMCOR has annual combined volume of over $5 billion. This provides PMI with the financial, bonding and insurance
capabilities to perform projects of any size and complexity.

PMI has a reputation for providing the highest level of skilled workmanship and for completing projects on schedule , with excellent relationship with clients including Roseville Electric . PMI’s safety and employee training programs have surpassed the standard requirements of the industry . As a local contractor, PMI is committed to the economy and workforce of the areas it serves. Over the years, PMI has developed strong relationships with local vendors and subcontractors that support its projects.

Highlights of PMI St rengths and Services:
• Pro-active safety program and excellent safety record, preventing needless loss of productivity due to incidents and resulting investigations.
• Ability to mobilize quickly, when needed, by moving company resources efficiently. • Ability to accurately measure performance, assess current and projected costs to enable strategic and informed cost and execution decisions throughout the project life cycle. • Ability to report costs daily to determine real-time strategic cost decisions and strategies. • Core value to report the reality to clients so proper decisions and strategies can be made. • A solid history and reputation for completing on time and within or under budgets. • Top down “whatever it takes” attitude and willingness to pitch in to achieve desired results. • Ability to adapt methods, procedures, and reporting to suit Client’s needs. • Reputation for being fair and honest with vendors and subcontractors to get the most qualified and cost-effective resources to Client’s facilities. PMI subcontractors are subject to an extensive pre- qualification process.
• All projects in the Sacramento area and central and northern San Joaquin valley are managed from Sacramento Region office located in Sacramento. This workload includes power, refining, food and

PERFORMANCE

MECHANICAL, INC (PMI)
Headquarters Office: Pittsburg, CA
Website: perfmech.com
Year established: 1985

SECTION A

FIRM'S QUALIFICATIONS
A-7
beverage, and water treatment projects. Clients in this region include SMUD, Pacific Gas and Electric (PG&E), Procter and Gamble, Anheuser Busch, Buckeye / Lodi Gas Storage, Calpine, Wood Group Power Operations, Turlock Irrigation District, and Carson Energy. • PMI team members included pipefitters, millwrights, boilermakers, carpenters and laborers for clients throughout California, with 300-500 union craftsmen at any given time.

Placer Electric, Inc. (PEI)
Placer Electric, Incorporated (PEI) is an electrical contracting firm serving Northern California and Nevada. PEI is one of the largest electrical contractors in the Sacramento Area and has served a varied clientele since 1978. The company’s
success has been achieved through sound management, an
outstanding technical and professional staff, experience in all phases of communications and electrical contracting, and a commitment to service and quality. PEI is extremely
committed to the safety of its staff and c lients, and the general public. All of the field staff are trained with the required OSHA specific training and must complete the
necessary site-specific training before being considered for a project.

Company Highlights:
• 6,541 satisfied clients
• 10,460+ completed projects
• 48 years in power industry services

General Electric
Founded in 1892, General Electric (GE) is a world leader in gas power technology, services, and solutions. Through
relentless innovation and continuous collaboration with our customers we engineer cleaner and more accessible energy that people depend on, powering growth and prosperity
everywhere. With the world’s largest installed base of gas turbines, GE offers advanc ed technology and a level of experience that is unmatched in the industry to build,
operate, and maintain leading gas power plants. As the world PLACER ELECTRIC, INC. (PEI)
Headquarters Office: Sacramento, CA
Website: placerelectric.com
Year established: 1978

GENERAL ELECTRIC
Headquarters: Boston, MA
Website: ge.com
Year established: 1892

SECTION A

FIRM'S QUALIFICATIONS
A-8
is shifting towards a lower carbon future, we are partnering with our power generation customers to help them succeed today, plan for tomorrow and be well positioned in the future.

Compass Energy Systems
Compass Energy Systems Ltd. is a private company of
experts in compression, gas processing, and power systems based in Canada and the United States. Compass specializes in engineering, design, and fabrication of high -quality energy systems with offerings that include package
assembly and support throughout the entire equipment
lifecycle. Beyond fabrication, Compass offers retrofit, parts, and field servicing services. Compass products are found in over 20 countries around the world.

Verve Industrial Protection (Red dy Kallem)
Founded in 1994, the firm grew from its early days through a relentless focus on customer service, expanding from one successful customer to the next. Today our legacy lives on in the 1,000+ automation and control system projects we have completed.

Our engineers have worked with every major DCS, PLC, and SCADA system on the planet.

We have worked closely with our clients on their most pressing network and data needs. We have helped them evolve their networks to manage the increasing amount of connectivity necessary to drive increased efficiency and reliability. We understand how these networks work, their vulnerabilities, and the unique operational characteristics that separate controls networks (operating technology or OT) from IT networks. We always put our customers first and work hard to maintain our 97% client retention rate.

R.E.Y. Engineers, Inc.

R.E.Y Engineers, Inc. is a civil engineering and land surveyor firm that provides civil engineering, land surveying, mobile LiDAR, terrestrial LiDAR, bathymetric surveying, and small unmanned aerial system surveying services.

COMPASS ENERGY SYSTEM LTD.
(COMPASS)
Headquarters Office: Houston, TX
Website: compassnrg.com

VERVE INDUSTRIAL PROTECTION
Headquarters Office: St. Louis, MO
Website: verveindustrial.com
Year established: 1994
R.E.Y. ENGINEERS, INC.

Headquarters Folsom, CA
Website: reyengineers.com
Year established: 1985

SECTION A

FIRM'S QUALIFICATIONS
A-9
Youngdahl Consulting
Youngdahl Consulting Group, Inc., is a full -service civil engineering, geotechnical engineering, environmental
compliance, and construction observation and materials testing firm working throughout northern and central California. The firm offers a complete range of consulting services, from conceptual planning through project completion on a large portfolio of projects. Founded in 1984, Youngdahl provides innovative engineering solutions to complex project problems.

Whether collaborating with other design consultants or working independently, our experienced team of trusted advisors works closely with each client to provide a broad range of in tegrated services which are cost effective and adeptly combine client interests, peer scrutiny, and regulatory requirements.

Trinity Consultants
Trinity has assisted clients with nearly 500 power- related projects, offering an array of services, such as federal air permitting, due diligence environmental investigations, regulatory and environmental compliance management, and environmental regulations training.

Notable Regulations, Standards & Codes
• Turbine NESHAP
• Affordable Clean Energy Rule
• Emissions Monitoring and Reporting Requirements
for Fossil Fuel-Fired Electric Generating Units
• Clean Air Act
• Title V Permitting Program
• GHG Regulatory Reform
• Energy & Air Quality Regulation
• Cross-State Air Pollution Rule (CASPR)
• AERMO

YOUNGDAHL CONSULTING
Headquarters Office: Rocklin, CA
Website: youngdahl.net
Year established: 1984

TRINITY CONSULTANTS
Headquarters Office: Sacramento
Website: trinityconsultants.com
Year established: 1974

SECTION A

FIRM'S QUALIFICATIONS
A-10
Power Systems Testing Co.

Power Systems Testing Company (PST C) is a full-service company relating to electrical power systems and testing. They provide acceptance or assurance testing on newly installed equipment and systems to confirm compliance with operating and safety standards. PST C provides electrical testing and maintenance on existing operating systems to assure their continual safe and reliable operation. They provide engineering studies to determine proper sizing and settings of protective devices and field studies and measurements of electrical and physical parameters to determine that electrical power systems function with their design criteria. PST C is available for unexpected emergency conditions to work with , or provide, guidance to the client’s own electrical staff and provide consulting expertise for specific or unusual electrical occurrences. PST C’s staff of Registered Professional Engineers accomplishes engineering studies and services.

POWER SYTEMS TESTING CO.

Headquarters Office: Livermore, CA
Website: powersystemstesting.com
Year established: 1975

SECTION A

FIRM'S QUALIFICATIONS
A-11
A5. Added Value
At IEC, we go beyond being just a contractor —we become a trusted partner dedicated to the successful completion of your project. We view the RPP2 Repower Project from the City's perspective, ensuring that we not only meet but exceed expectations. Our team brings unique qualifications that provide significant added value, including:

Commitment to Safety
Safety is our top priority and a core value embedded in our corporate philosophy and general practices.

The well-being of our personnel, clients, subcontractors, and the surrounding community is paramount.

IEC ensures all job sites are staffed with highly trained personnel who hold the appropriate safety certifications. We meticulously monitor every aspect of the project to ensure compliance with all federal, state, and local safety regulations, as well as specific jobsite requirements established by our customers.

At IEC, we believe there is no excuse for poor safety management, and our clients should expect nothing less than an intentional and proactive approach to safety.

Corporate Stability & Strength
IEC Corporation has been a successful and profitable partner to electric utilities for over 25 years. With an established client base that includes major utilities across the West Coast, our solid reputation and long- term contracts affirm our financial strength and stability. Our current bonding capacity stands at $50 million per project, providing confidence in our ability to manage projects of any scale.

Local Presence for Rapid Response
With headquarters located in Sacramento, just a short drive from RPP2, IEC offers unparalleled responsiveness and communication. Our close proximity allows for quick site access, enabling us to conduct face -to-face meetings and on- site evaluations at short notice. This ensures our project management team remains closely aligned with Roseville Electric’s goals and requirements at all times.

Staff Continuity for Seamless Execution
Continuity of personnel is crucial to the success of complex projects. Our team comprises industry-leading experts with deep knowledge of City operations and expectations, ensuring seamless integration and execution. Dedicated lead engineers for each discipline will maintain consistency throughout the project, eliminating the need for extensive onboarding and allowing power plant staff to focus on operations without the burden of training new contractors.

Unmatched Familiarity with Roseville Electric
With over eight years of direct experience supporting Roseville Electric, IEC has built strong working relationships with plant engineers, managers, supervisors, operators, and maintenance teams. Our extensive knowledge of the City’s standards, policies, a nd procedures —combined with our hands -on experience—ensures we can execute projects with unmatched efficiency.

SECTION A

FIRM'S QUALIFICATIONS
A-12

Experienced Professional Utility Engineers
This project demands engineering expertise at a utility scale, and IEC delivers with a team of California Registered Professional Engineers across all key disciplines —electrical, mechanical, civil, structural, and instrumentation & controls (I&C). Our exte nsive experience working with public agencies ensures compliance with utility procedures, rigorous safety standards, meticulous documentation, and superior quality control.

Dedicated After-Hours Support
IEC is committed to providing responsive, first -class service whenever needed. We guarantee prompt responses to inquiries within hours and are prepared to work beyond standard business hours to meet the City's needs and project deadlines. Our dedication en sures that the City will receive exceptional support and professional construction services, exceeding expectations at every stage of the project.

SECTION A

FIRM'S QUALIFICATIONS
A-13

SECTION A

FIRM'S QUALIFICATIONS
A-14

ORGANIZED 1887  IRRIGATION WATER 1904  POWER 1923  DOMESTIC WATER 1994

1231 Eleventh Street
P.O. Box 4060
Modesto, CA 95352
(209) 526-7373

August 24, 2017

To Whom It May Concern,
RE: IEC Corporation

It is my pleasure to write this recommendation for IEC Corporation with regard to their engineering services for the Modesto Irrigation District on the Woodland Generation Station Unit 2, Woodland Generation Station Unit 3, and Ripon Generation Station. IEC provided construction management and owner’s engineer services on all three plants during the engineering, procurement and construction phase. They brought a very professional and experienced team that worked well with the various contractors and was well respected.

IEC staff was able to adjust to the varying schedules and expectations and support completion of the projects on time and within the budget established. They possess the rare ability to bring all of the required components for the project into focus and effectively work with other team members toward an established goal of quality and timeliness.

MID has worked on projects for 15 years with IEC and I have always found their team approach yielded effective results and was the basis for successful projects. They have been extremely responsive and provided a quality work product at a reasonable rate.

IEC has demonstrated professionalism through thei r services and I highly recommend them to any organization looking for a very talented engineering firm.

Should you need anything further or have any questions , please feel free to contact my office at (209) 526-7550.

Sincerely,

Greg Salyer
General Manager

O
ctober 1, 2021

Regarding: IEC Corporation

To Whom It May Concern,

It is my pleasure to write this recommendation for IEC Corporation with regard to their engineering and
consulting services. IEC provided engineering design services and startup and commissioning support for the City of Palo Alto Utilities Department on the Hanover Substation Relay Replacement project. The City replaced outdated protection relays and associated feeder controls equipment on six (6) 12.47 kV distribution feeders. The scope of work included creating the design package for construction, developing protection settings, and creating relay programming files for the new SEL relays, preparing a startup and commissioning plan, providing technical support during construction, providing onsite startup and commissioning support, and providing as-built drawings. IEC brought a very professional and experienced team that worked well with the City staff and was well respected.

T
he IEC team provided a rare combination of real-world experience coupled with the willingness to transfer that experience and knowledge in ways to positively impact the project. From recommendations on equipment, introducing alternative operational procedures, to implementing difficult protection scheme’s, they brought unique solutions to site-specific problems. They understood our needs and effectively addressed any concerns we had.

T
he onsite startup and commissioning support provided by IEC was especially useful in troubleshooting relay testing software issues and performing onsite calculations to determine the appropriate test results.

IEC demonstrated a strong ability to bring all the required components of a project into focus and effectively work with City staff to accomplish the startup and commissioning in a timely manner.

T
he City of Palo Alto Utilities Department has worked with IEC Corporation on several projects, and have always found them responsive, easy to work with, and provide a quality work product which result s in successful projects. IEC has demonstrated professionalism through their services, and I highly recommend them to any utility or city government looking for a very talented engineering firm.

S
hould you need anything further or have any questions, please feel free to contact my office at (650) 566-4551.

S
incerely,

Mike Mintz
Mike Mintz
Senior Electrical Engineer
City of Palo Alto Utilities

LW]LJJ

IN IN 1111M IN 11 D
tecanffi
Victoria Brunn, Coordinator: Sustainabüity and Energy Education d Schoo' Dtrid
Date: February 10, 2014
Subject: Letter of Recommendation, IEC Corporation
To Whom It May Concern:

The IEC Team acted as the general contractor for Manteca Unified School District's $30 million Renewable Energy Efficiency Project (REEP) that included installation of 26 solar PV systems across the District. I had the pleasure of working with them during the preliminary design phase of the solar systems and appreciated their professionalism and attention to detail when it came to individual site considerations and constraints. Their Team was personable and responsive to our staffs questions and worked diligently to make the project as streamlined as possible for our Facilities staff. Additionally, the IEC Team has been a valued partner in education and a popular presenter at our Planet Party events for 6th graders. IEC also continues to participate as a member of the District's Leadership on Green Initiatives Committee (L.O.G.I.C) and provide input for Planet Party planning and other green projects.

Sincerely -"
Victoria Brunn
Coordinator: Sustainability and Energy Education
P.O. Box 32 Phone (209) 825-3200
Manteca, CA 95336 Fax (209) 858-7570
2271West Louise Avenue, Manteca, CA 95337 www.mantecausd.net

Board of Trustees: Paul Green, Jennifer Winter, Johnny L. Smith, John H. Lorona, Roger Orosco Superintendent: Mark G. Sutton
Equal Opportunity Employer

SELMA UNIFIED SCHOOL DISTRICT
3036 THOMPSON AVE., SELMA, CA 93662

(559) 898-6500 FAX (559) 896-7147
January 10, 2014

Subject: Letter of Recommendation
Integrated Engineers and Contractors

To Whom It May Concern:

I had the pleasure of selecting and working with Integrated Engineers and Contractors (IEC) on Selma USD’s $13 million solar panel project. IEC assisted with planning the project and did the design work.

They chose and supervised all of the subcontractors on the job.

The many challenges associated with the program required teamwork, leadership and dedication to ensure the SUSD’s interests were protected. Due in large part to the management expertise and commitment of IEC and its staff, the projects were completed on schedule and on budget. Using an active and cooperative management approach, IEC has facilitated informed decision-making at all levels of the project from start to finish.

IEC’s construction management expertise was evident in many facets of the program. Their ability to plan, coordinate and implement the projects allowed for a smooth running program. Their consistent performance was key in resolving issues, communicating solutions and minimizing overall impacts to the projects.

Their assigned management staff was instrumental to the success of the projects. Their extensive knowledge and experience, coupled with diligence and hard work, has made working on this program so much easier and less stressful than other projects that I have been involved with. From the start, their professionalism, knowledge and experience have shined through.

I highly recommend IEC for your solar needs—particularly on complex projects. Please do not hesitate to contact me should you need any additional information.

Sincerely,

Larry Teixeira
Assistant Superintendent

SECTION B

EXPERIENCE & REFERENCES

SECTION B

EXPERIENCE & REFERENCES

EXPERIENCE AND REFERENCES

Introduction
This Section includes a detailed description of our Team’s extensive experience related to the scope of work for the RPP2 Repower Project.

• Section B.1 presents the Team’s technical experience through project examples.

• Section B.2 presents the Team’s quality of support through an extensive list of project references.

Together, they provide an in-depth overview of our value and what the City can expect from the IEC Team.

SECTION B

EXPERIENCE & REFERENCES

B.1-1

B.1 TEAM’S EXPERIENCE

Proven Experience
To demonstrate the Team’s technical breadth and depth, this section includes detailed examples of our proven experience related to all aspects of utility scale gas fired power plant facilities.

The section is divided by company to highlight each company’s expertise and experience. Table B -1 summarizes the number of project examples included for each company.

Table B-1
Summary of Project Samples

Company Area of Expertise Number of Project Examples
IEC Corporation
General Contractor, Project
Management Engineering
& Design
3 project example narratives related to IEC’s specific
familiarity with the City of Roseville power facilities; 14 project narrative examples related to IEC’s
overall experience in power plant design and
implementation.

Performance
Mechanical, Inc. Mechanical Contractor
A list of over 100 project examples related to BOP
construction; 5 project narrative examples
demonstrating experience with similar scopes of
work.

Placer Electric, Inc. Electrical Contractor A list of 21 project examples related to electrical installation performed at Roseville Energy Park.

Western States Fire
Protection Fire Protection Contractor 20 project examples demonstrating the breadth of experience on a wide variety of projects.

Verve Industrial
Protection Controls Specialist
4 project example narratives highlighting Verve’s
(Reddy Kallem) experience with Ovation control
system integration.

REY Engineers, Inc. Civil Engineering 2 project example narratives demonstrating a wide range of civil service and experience.

Youngdahl Consulting
Group Geotechnical Engineering
3 project example narratives related to the
environmental, geotechnical, and geologic
engineering and studies performed on large-scale
projects.

Trinity Consultants Permitting Specialist 8 project examples related to emissions and air quality reports, assessments, permits and licensing.

Compass Gas Compressor Supplier A list of over 100 project examples related to 300 HP and higher projects.

Power Systems
Testing Co. Electrical Testing A extensive list of clients, including Utilities, Cogeneration Facilities and Hydro-Electric Projects.

SECTION B

EXPERIENCE & REFERENCES

B.1-3

Gas Turbine Experience
The following summary demonstrates the IEC’s extensive experience with gas turbine power projects.

CLIENT PROJECT NAME CONTRACT #

TURBINE/

CONFIGURATION MEGAWATTS ROLE & SERVICES

PROJECT
SIZE
Modesto Irrigation
District WGS1 Conversion MID8-36 GE LM6000 Simple Cycle 50 MW Engineering, Construction Management $31 M
Roseville Electric
Utility RPP2 Rehabilitation PO 9006739 GE Frame 5 Simple Cycle 48 MW Engineering, Procurement, Construction (EPC) $9 M
International Paper Mansfield Repower IP-WS1 GE LM6000 Simple Cycle 45 MW Engineering, Procurement, Construction (EPC) $30 M
Roseville Electric
Utility
Master Services
Agreement K1801198 Siemens SGT-800
Combined Cycle (2x1) 160 MW Project Management, Engineering, Technical Support $1.25 M
Roseville Electric
Utility
Master Services
Agreement PO 9006428
Siemens SGT-800
Combined Cycle (2x1)
GE TM2500 (2 Peakers)
160 MW &
60 MW
Project Management, Engineering,
Technical Support $2 M
Liberty Power Algonquin Sanger
Cogen Repower ALG3 GE LM6000 PC SPRINT
Combined Cycle 57 MW Detail Design, Project Management, Construction Management $10 M
Anchorage Municipal
Light & Power
George M. Sullivan
Power Plant 2
Expansion
ANC1 GE LM6000 PF SPRINT
Combined Cycle 120 MW
Construction Management, Owner's
Engineering, Project Management,
Design, Inspection
$306 M
Turlock Irrigation
District
Almond 2 Power
Plant Expansion TID5 & TID6 GE LM6000 PG SPRINT
Simple Cycle 200 MW Construction Management, Project
Management, Design Review $200 M
Modesto Irrigation
District
Ripon Generation
Station MID2,3,5 GE LM6000 PC SPRINT
Simple Cycle 100 MW
Project Management, Construction
Management, Owner's Engineering,
Design
$65 M
Public Service
Company of New
Mexico
La Luz Energy Center LLEC-NM GE LM6000 PC SPRINT
Simple Cycle 50 MW Detail Design and Engineering $60 M

CLIENT PROJECT NAME CONTRACT #

TURBINE/

CONFIGURATION MEGAWATTS ROLE & SERVICES

PROJECT
SIZE
San Diego Gas &
Electric
Palomar Energy
Repower Project SDGE1 GE LM6000 PC SPRINT
Simple Cycle 50 MW Detail Design and Engineering $30 M Sacramento Municipal
Utility District
Procter & Gamble
Cogen Plant SMUD-PG GE LM6000 PC SPRINT
Simple Cycle 45 MW Design and Construction
Management $50 M
Modesto Irrigation
District
Woodland
Generation Station
Unit 2
MID3 GE LM6000 PC SPRINT
Combined Cycle 80 MW Project Management, Design,
Construction Management $60 M
Los Angeles Dept. of
Water & Power
Haynes Generating
Station Retrofit LADWP-HGS GE Frame 7FA Combined
Cycle 500 MW Construction Management, Quality
Assurance $100 M
Redding Electric Plant Engineering
and Design RED2 Gas Turbine 50 MW Engineering Design $5 M Fresno Cogeneration
Partners
Fresno Peaker
Facility FRESNO1 FT-4 Power Pac
Combustion Turbine 50 MW Project and Design Engineering $20 M Sacramento Municipal
Utility District
Cosumnes Power
Project SMUD5 GE Frame 7FA Combined
Cycle 500 MW Construction Management, Project
Management, Design Review $500 M
Sacramento Municipal
Utility District
McClellan Peaker
Project SMUD6 GE 7EA Peaker Plant 80 MW Owner’s Engineering Services and Construction Management $10 M

IEC PROJECT EXPERIENCE

ENGINEERING DESIGN
• Process Flow Diagram
• P&IDs
• Anchorage & Foundation Plan & Details
• Piperack Plan & Detail Sheets
• Mechanical Layout Plan & Detail Sheets
• 3D Equipment Modeling
• Water Balance
• Equipment Specifications
• Single Line Diagrams
• Three Line Diagrams (Above 480V only)
• Grounding & Lightning Protection Drawings
• Raceway Layout Plan & Detail Sheets
• Conduit/Cable Fill Reports
• Wiring Diagrams
• Structural/Mechanical/Electrical Calcs.
• Field Engineering
Project
Reference:

Paul Mercer
209-529-7616
[email protected]
Contract: $2,500,000
Contract Date: 2023
Woodland Generation Station 1
Repower Project
Client: Modesto Irrigation District (MID)

IEC was responsible for the complete detail design
and construction management of the Woodland
Generation Station 1 (WGS1) Conversion Project for
Modesto Irrigation District. The project entail ed
converting the existing LM5000 turbine package to a
GE LM6000 PC SPRINT hot end drive package.

In addition to converting the gas turbine, t he project included demolishing the existing HRSG and replacing
it with a new and complete exhaust duct and stack
along with a new ammonia injection system. The
project also included installing a new packaged chiller system and modifying the existing medium voltage
electrical systems.

IEC evaluated and designed the entire conversion
including removing the existing steam systems and
updating the remaining balance of plant systems to
support the new GE LM6000 unit.

Once the project was in construction, IEC was
responsible for managing the entire project in the
field including directing all construction work. IEC
provided construction management, field
engineering, QA/QC assurance, inspections,
equipment management, and budget management to
ensure the project was built to specifications. IEC
coordinated work between all the trades and the
equipment suppliers including GE technical advisors in
the field. The plant successfully achieved commercial
operation in October 2023.

IEC PROJECT EXPERIENCE

Roseville Power Plant 2 (RPP2) Rehabilitation Project
Client: Roseville Electric Utility
IEC Corporation provided complete turnkey project management , engineering, equipment procurement, construction/installation, and commissioning services for the rehabilitation of Roseville Power Plant No. 2 (RPP2) . RPP2 is a simple cycle facility consisting of two GE MS5001P (Frame 5) combustion turbines and associated auxiliary equipment. The rehabilitation efforts primarily focus ed on overhauling the gas turbine units and upgrading the aging excitation and control systems to improve start reliability and sustained cyclic operation.

IEC performed the following planned scope of work on a turnkey basis including engineering, procurement, and construction in Phase 1 outage in 2021.

• Perform Gearbox Inspections
• Perform Generator Inspections
• Upgrade Bleed Valves
• Replace Excitation System in one CT Package
• Repair Fuel Nozzles
• Repair Transition Pieces
• Replace 1st and 2nd Stage Nozzles
• Performed Combustion Inspection and Hot Gas Path Inspection • Performed Cleaning/Inspection/Testing of all MCCs
• Upgrade Instruments
• Resolve P2 Pressure Issue
• Re-commission Plant

In addition, IEC performed the following unplanned tasks as a result of the findings from the planned tasks.
• Performed Major Overhaul on One CT
• Performed Generator Overhaul, Testing, Cleaning, Stator/Rotating Field Inspection on One Generator

In Phase 2 outage in 2022, IEC will replace the control systems for both CT package s and replace the excitation system in one CT package.

QUALIFICATION CRITERIA
 Role: General Contractor
 Combined Cycle
 Simple Cycle
 Retooling
 Major Modifications
 Public Utilities

IEC PROJECT EXPERIENCE

For the Phase 1 outage work, IEC was given 6
months to complete all of the planned tasks
from client’s notice to proceed. IEC met the fast-
track outage schedule by completing the
planned and unplanned tasks on time before
the summer season.

IEC’s cooperative approach, dedications,
knowledge and understanding of power plant
operations are what clearly set IEC apart from
other prime contractors and competitors.

Contract Number: PO #9006739
Project Reference:

Mr. Nathan Ribordy, P.E.,
Plant Engineering Manager
Roseville Electric Utility
[email protected]
916-746-1673
Professional Fees:

Construction Fees:

Material Fees:

TOTAL:
$2,825,740
$2,371,148
$3,795,752
-------------------------------
$8,992,640
Contract Dates: Jan 2021 to May 2022

IEC PROJECT EXPERIENCE

IP Mansfield Repower Project
Client: International Paper

For the International Paper Mansfield Repower Project,
IEC was awarded the Engineering Design and
Construction contract to repower an aging GE Frame 5
turbine package with a GE/WattStock TUREPackage
with LM6000 PF SPRINT turbine.

During the Engineering Design phase, IEC developed a
detailed 3D model and engineered the necessary Issued
for Construction (IFC) documents (including demolition, mechanical, electrical, civil, structural, and
instrumentation and control drawings).

During the Outage Conversion phase, IEC’s scope of work included 1) removing the GE Frame 5 turbine package and placing it in storage area in resellable condition and 2) installing the new repower equipment.

IEC was contracted to complete the construction within four (4) weeks based on client’s outage schedule.

IEC provided 24-hour around the clock construction along with on-site field engineering and management (same staff during design phase) to support the construction progress seamlessly. IEC was able t o complete the construction scope on time and on budget for startup and commissioning.

Throughout the project, IEC took every measure and went above and beyond the scope of work to demonstrate IEC’s commitment and team spirit to the overall project success. IEC expedited the engineering without change orders to maintain the construction start date and worked around the clock (24/7) for 3 weeks to achieve substantial completion.

IEC PROJECT EXPERIENCE

Master Services Agreement Generation Engineering Support Client: Roseville Electric Utility
IEC has been awarded two (2) Master Services contracts with the Roseville Electric Utility c onsisting of multidisciplinary engineering services (electrical, civil, structural, mechanical, instrumentation and control, telecommunication, fire protection, etc.) for the Roseville Energy Park (REP) and Roseville Power Plant 2 (RPP2) generation facilities on an as-needed basis. To ensure responsive and effective engineering services both for scheduled projects and emergency unplanned outages, IEC has remained responsive to provide qualified and experienced project managers, engineers and other technical support staff upon individual request to meet the City’s schedule and operation requirements . Our cooperative approach , dedications, knowledge and understanding of power plant operations are what clearly set IEC apart from other prime contractors and competitors.

Work Authorizations: Work Authorizations included 59-plus tasks to date:

Civil/Structural
• Civil and Structural Plant Improvements
• Steam Turbine Enclosure Structural Engineering

Mechanical
• Boiler Feedwater Pipeline Engineering
• Trunnion Design and Structural Engineering Support
• RPP2 Generator Protection Upgrade
• Detailed Engineering Cost Estimates
• REP Electric Boiler Preliminary Engineering Feasibility Study • RPP2 Fire Protection Specification Development
• RPP2 Fire Protection Construction, Startup and Commissioning Support • Inlet Chiller Evaluation
• RPP2 Exhaust Liner Retrofit Design Engineering and Construction Support
• REP Steam Turbine Blanket Electrical Design and Support • REP Siemens Turbine Upgrade Permit Mod & CEC Amendment • REP Permitting Support & GateCycle Thermal Modeling
• GateCycle Model Tuning and Plant Performance Investigation • Boroscope Inspection Services at RPP2
• RPP2 Fire Protection Specifications
• RPP2 Exhaust Liner Retrofit Engineering & Construction Support • CT1 Fire Protection System Management
• REP ZLD Improvements Engineering Support
• REP Ammonia Control Tuning
• Engineering Support for the Screw Press Project

QUALIFICATION CRITERIA
 Combined Cycle
 Simple Cycle
 Retooling
 Major Modifications
 Public Utilities

IEC PROJECT EXPERIENCE

• REP STG Thermal Blanket Updates
• Controls Specialist for ZLD Controls Upgrade & Revenue Meter Upgrade • RPP2 Control TA Support
• REP Revenue Meter Upgrade
• REP Chiller Evaluation

Electrical
• RPP2 General Electrical Engineering Support
• REP Protection Engineering Support
• General Electrical Engineering Support
• RPP2 Generator Protection Upgrade Field Engineering and Construction Support • Arc Flash Hazard Analysis at RPP2 & REP
• Arc Flash Hazard Training
• RPP2 Generator Protection Relay Upgrade
• RPP2 Generator Protection Upgrade Construction Support

Instrumentation and Controls
• REP AGC Control Improvement Project
• REP Emerson Remote I/O Control Relay Failure Investigation • REP AGC Control Phase 2 Improvement Project
• REP AVR/PSS Upgrade Engineering Support

Drafting
• Professional Drafting Services to update plant drawings • REP Drawing Consolidation
• RPeak As-Built Drawings

Onsite Support
• Construction Administration and Support for various plant projects

Miscellaneous
• REP and RPP2 Security Evaluation
• Asset Retirement Cost Estimate
• REP and RPP2 Spill Prevention Control and Countermeasure (SPCC) Plant Development • REP CT1 Start Motor Feasibility Study
• REP Thermal Storage Evaluation

Contract
Number: K1801198
Project
Reference:

Mr. Nathan Ribordy,
Plant Engineer
[email protected]
916-746-1673
Contract: $1,141,876
Contract Dates: 2017 to 2022
Contract
Number: PO 9006428
Project
Reference:

Mr. Nathan Ribordy,
Plant Engineer
[email protected]
916-746-1673
Contract: $1,027,450 (billed to
date)
Contract Dates: 2020 to 2025

IEC PROJECT EXPERIENCE

Sanger Cogeneration Repower – Owner’s
Engineering, Construction Management, & General Contractor Services Client: Liberty Power (formerly Algonquin Sanger Power) IEC provided preliminary design, detailed design, project management and Construction Management services for the Sanger Cogeneration Repower Project . The project was a repower of an existing Westinghouse 251 with a GE LM6000 PC Sprint at the Algonquin Sanger Cogeneration Facility for a total net plant generating capacity of 57 MW.

Preliminary Engineering Study: IEC initially performed an engineering feasibility study, with value engineering, which included developing a power plant simulation model using GE Gatecycle software to predict performance characteristics and adequacy of the existing equipment with the LM6000 PC or PC SPRINT combustion turbine. Major equipment includes two pressure level HRSG with SCR, 13 MW Westinghouse steam turbine, condenser, cooling tower, and water treatment facility. The study included project cost estimate, site plan layout, repowe r project scope of work, site plan review proposal for City of Sanger, and photo simulation of the plant with the new LM6000 turbine.

LM6000 Turbine Inspection: IEC inspected
the condition of a new LM6000 S&S package that
had been in storage for 4 years. IEC r eviewed
documentation for completeness, itemized and
prioritized turbine upgrades product bull etins
and service bulletins package options, and
prepared a final recommendation to the client.

Repower Project Design: IEC performed the complete detailed design of the repower project. Responsibilities included equipment specifications development, bid evaluation, equipment procurement, vendor coordination, P&ID and drawing development, building permit application process, construction bid package development, mechanical design, structu ral design, natural gas system modification with new compressors system, natural gas emergency shutoff system design, anti -icing system design, turbine inlet coil des ign, DI water system modification, cooling water system modification, boiler blowdown system modification, turbine exhaust duct elbow modification, and steam turbine bypass system design.

Construction and Start -up Management: IEC engineers provided construction management services, including scheduling, field engineering support, project management support, contractor coordination, design review, document control, interfacing with City Building Department, and field inspection services. IEC oversaw TTSC as they performed the construction work. TTSC performed construction of the LM6000 PC SPRINT turbine and its ancillary equipment in parallel with existing plant operation. Upon full installat ion of the new equipment, TTSC decommissioned and removed the existing W251 Westinghouse gas turbine. A new turbine exhaust elbow was installed and tied-in with the existing HRSG. Other equipment such as natural gas compressor system and anti -icing system were also installed and connected. The repower construction was completed in six months, with a plant outage period of only 45 days.

QUALIFICATION CRITERIA
 Combined Cycle
 Retooling
 Major Modifications
Project Reference:

Paul Grady
559-470-7994
[email protected]
Professional Fees:

Construction Fees:

Material Fees:

TOTAL:
$358,034
$161,888
$33,462
-----------------------------
$553,384

IEC PROJECT EXPERIENCE

George M. Sullivan Power Plant 2 Expansion
Project Engineering & Construction Management
Client: Anchorage Municipal Light & Power

IEC provided Owner's Engineering
and Project Management services
to Anchorage Municipal Light &
Power to support the
development of a 120 MW, 2x1
combined cycle power project
that is designed to be the new primary base load facility for the utility.

The Project was selected by Engineering News and Review as the ENR Northwest Owner of the Year for 2015.

IEC's initial work included developing design documents for a separate site preparation contract and analyzing the potential for teaming with the local water district to make use of waste heat. After the initial contract, AML&P awarded IEC with a $6.9 million, two-and-a-half year contract extension to continue its on -site support and provide construction management, design review, field engineering, and special inspection services. Our team has been embedded with AML&P from Day one, collaborating on develop ment of project scope, specifications and project execution.

The project includes an innovative cooling system design coupled with the water district to capture more than 50% of the plant's annual waste energy to heat the community potable water supply for the City of Anchorage. Additional waste heat will be used for a mass snow melt system on site. The cold, upstream City water will be used to cool the turbine combustion air during warm summer days. The new power plant is approximately 25 percent to 30 percent more efficient with a combined-cycle design that combines gas-fired turbines with sufficient waste heat recovery to drive an additional steam turbine.

The site makes use of a plume -abated cooling tower and a full Gas Insulated Switchgear (GIS) substation and switchyard. The administration building will also serve as the utility's new power generation engineering offices and will house a backup dispatch center for emergency situations.

ENGINEERING TASKS
• Project plan
• Feasibility Analysis
• Safety & regulatory compliance
• Outside services contracts
• Project communications and
reporting
• Management briefings
• Change orders
• Project performance
evaluations
• AML&P contracts and standards
evaluation
• Agency approvals
• Cost estimates
• Budget reviews
• Scheduling and progress
reporting
• Submittal management
• Constructability review
• Risk management
• Information management
• Quality control engineering
• Closeout and turnover
• Document control
• AML&P interface
• AML&P representation
• Project controls
Project Reference: Eugene Ori, [email protected], (907) 279-7671 Project Value: $200 Million+
Professional Fees: $11.4 Million

IEC PROJECT EXPERIENCE

Almond 2 Power Plant Expansion
Project Engineering & Construction Management
Client: Turlock Irrigation District

As Project Manager and Construction Manager for the Almond Power Plant Expansion, IEC provided a wide range of project engineering, technical expert support, and project oversight throughout all phases of the Project as described below.

Preliminary Engineering & Cost Estimate: IEC developed six (6) preliminary site plan options for 50 MW, 100 MW, 150 MW and 200 MW power plant scenarios. IEC used various combinations of gas turbines including GE LMS100 and GE LM6000
units and presented the TID
with six cases and layouts for
varying capacities and
configurations. The layouts
were based on the actual size
of the equipment needed
including all the balance of
plant equipment. IEC
performed preliminary
engineering and worked with
reputable vendors to size and
select the equipment. IEC also prepared water balances for all six options. In addition, IEC prepared detail ed total capital cost estimates for all six cases covering development, licensing, permitting, emission offsets, engineering, procurement, construction, start-up, and testing. The estimate was accurate down to the skid level. The cost estimate was adjusted for union considerations and escalated for the cost of raw materials.

Equipment Recommendations: Based on IEC’s preliminary engineering and recommendations, TID selected three 58 -MW General Electric LM6000PG turbines equipped with a water injection system to the turbine in order to reduce nitrogen oxide (NOx) formation, and a selective catalytic reduction system to further control NOx emissions.

ENGINEERING TASKS
• Day-to-day operations
• Project plan
• Design packages
• Consulting services
• Safety & regulatory compliance
• Outside services contracts
• Project communications and
reporting
• Management briefings
• Cash flow projections
• Change orders
• Project performance evaluations
• TID contracts and standards
evaluation
• Agency approvals
• Cost estimates
• Budget reviews
• Scheduling and progress
reporting
• Submittal management
• Constructability review
• Risk management
• Information management
• Quality control engineering
• Closeout and turnover
• Document control
• TID interface
• TID representation
• Project controls

IEC PROJECT EXPERIENCE

Construction Management & Field Engineering: Due to IEC’s design experience, operational knowledge, and ability to maintain project quality, TID requested that IEC provide complete construction management and engineering oversight for all disciplines including mechanical, electrical, civil/structural, and controls engineering. IEC provided support throughout the construction phase to manage contractors and maintain permitting compliance.

Our experts also provided specialized documentation, inspection, and training to ensure successful commissioning, start-up, and long-term reliability. IEC’s field team was responsible for achieving Mechanical Completion on schedule and with no claims. TID has since tasked IEC with ongoing site engineering support for plant operations. IEC will be available on an as -needed basis to coordinate, track, and resolve electrical engineering issues at the facility. IEC recently wrapped up its successful on-site support of the Turlock Irrigation District’s (TID) Almond Power Plant Expansion Project.

Project Reference: Mr. George Davies, [email protected], (209) 883-3451 Project Value: $200 Million+
Professional Fees: $1,056,150

IEC PROJECT EXPERIENCE

Ripon Generation Station
Owner’s Engineering & Construction Management
Client: Modesto Irrigation District

As a result of our responsiveness and quality of performance for the Woodland Unit 2 Project, MID contracted with IEC to completely manage their next project which was a 100 MW power plant project located in Ripon, California. MID gave IEC a sole source contract to serve as Owner’s Engineer, Project Manager and Construction Manager for the Ripon Generation Station. The peaking facility consists of two (2) GE LM6000 natural-gas-fired combustion turbine generators in simple cycle configuration. Additional components include new 69kV subtransmission line and fiber optic cable, new 8 -inch diameter natural gas pipeline, a nd tie -in lines into the City of Ripon water supply and wastewater lines.

IEC initially performed an evaluation for a variety of gas turbines. The evaluation compared performance, reliability, operational flexibility, maintenance, emissions and installed cost. The data was used to determine the "best fit" for MID based on their power needs and operational requirements. From the evaluation, MID was able to select the power generation configuration and resulted in the purchase of two LM6000’s from GE at under market price with several options included at no charge to MID.

IEC provided design review, scheduling, engineering, construction management, field inspection services, and project management support for the project. The project was successfully installed, completed, and providing power in April of 2006.

The client was pleased with IEC’s support and our ability to pull the schedule back onto track even though the project had incurred some delays due to equipment delivery and design issues.

ENGINEERING TASKS
• Day-to-day operations
• Feasibility analysis
• Consulting services
• Project plan
• Safety & regulatory
compliance
• Outside services
contracts
• Project
communications and
reporting
• Management briefings
• Cash flow projections
• Change orders
• Project performance
evaluations
• MID contracts and
standards evaluation
• Agency approvals
• Cost estimates
• Budget reviews
• Scheduling and
progress reporting
• Submittal
management
• Constructability
review
• Risk management
• Information
management
• Quality control
engineering
• Closeout and turnover
• Document control
• MID interface
• MID representation
• Project controls
Project Reference: Greg Salyer, [email protected], (209) 526-7617 Project Value: $65 Million+
Professional Fees: $700,000

IEC PROJECT EXPERIENCE
La Luz Energy Center
Client: Public Service Company of New Mexico
IEC Corporation provid ed professional engineering services in support of the La Luz Energy Center Project (LLEC). This project consists of the installation of an LM6000 PC SPRINT in simple cycle configuration on behalf of Public Service Company of New Mexico (PNM). The site of the proposed project is located in a rural area adjacent to the PNM Belen Reactor Station/Belen Substation in Belen, New Mexico. Generation will step up from 13.8KV to 115 KV and pass‐thru to PNM’s Belen substation, via approximately 500 ft of overhead transmission line. IEC Corporation provided design engineering services and project document control as part of the contractors on the PEPC team (Permit, Engineer, Procure, and Construct).

ENGINEERING TASKS
• Design packages
• Project communications and
reporting
• Management briefings
• Information management
• Quality control engineering
• Closeout and turnover
• Document control
• Contractor interface
• Project controls
Project Reference: Turner Scholl, [email protected], 916-505-5676 Professional Fees: $709,778

IEC PROJECT EXPERIENCE

Palomar Energy Plant Repower Project, Escondido, California Client: San Diego Gas & Electric
The Palomar Energy Plant in Escondido, California serves the growing energy needs of the greater San Diego area . IEC teamed up with TTS Construction on this Engineer, Procure, Construct (EPC) project. This project consisted of installing an LM6000 PC SPRINT in simple cycle configuration on behalf of San Diego Gas & Electric . IEC Corporation provided complete design engineering services. IEC’s responsibilities included complete detailed engineering,.

QUALIFICATION CRITERIA
 Combined Cycle
 Simple Cycle
 Retooling
 Major Modifications

IEC PROJECT EXPERIENCE

Procter & Gamble Cogeneration Plant
Client: Sacramento Municipal Utility District
The Procter & Gamble Cogeneration Plant, also referred to as the SCA Cogen II, is owned by the Sacramento Municipal Utility District. The 120 MW power plant, located adjacent to the Procter & Gamble Manufacturing Facility in
Sacramento, California, is powered by GE LM6000 CTGs in a combined cycle configuration. IEC was contracted to
provide field engineering and inspections throughout the entire construction phase for the new plant.

IEC PROJECT EXPERIENCE

Woodland Generation Station Unit 2
Owner’s Engineering & Construction Management
Client: Modesto Irrigation District

The Modesto Irrigation District (MID) retained IEC to provide owner’s engineering, project management, and construction management services for the development and construction of a new 80 MW gas turbine generating facility owned and operated by MID. The p lant consists of a 47 MW GE LM6000 Sprint combustion turbine generator in combined cycle with a single 37 MW steam turbine generator. A state of-the-art, customized duct-fired heat recovery steam generator allows the plant to use the steam turbine for load following and produce 80 MW net power at full -load condition. The plant also includes the Mark VI Control System, 2000 -Ton Chiller, SCR and CO Emissions Systems and Cooling Tower.

Due to IEC’s responsiveness and quality of work, the contract expanded from $150,000 to $900,000 to perform design reviews, provide construction management, prepare a complete engineering and construction schedule, develop a detailed budget schedule, provi de full-service construction management and oversee additional management services for the Owner. IEC provided on -site support throughout the construction phase to monitor site work and contractors and maintain compliance.

IEC’s field team was responsible for achieving Mechanical Completion on schedule and with no claims. The project was successfully installed, completed, and providing power in 2003. The client was extremely pleased with our responsiveness and quality of performance and contracted with IEC to completely manage their next power project.

ENGINEERING TASKS
• Day-to-day operations
• Consulting services
• Project plan
• Safety & regulatory compliance
• Outside services contracts
• Project communications and
reporting
• Management briefings
• Cash flow projections
• Change orders
• Project performance evaluations
• MID contracts and standards
evaluation
• Agency approvals
• Cost estimates
• Budget reviews
• Scheduling and progress
reporting
• Submittal management
• Constructability review
• Risk management
• Quality control engineering
• Closeout and turnover
• Document control
• MID interface
• MID representation
• Project controls Project Reference: Greg Salyer, [email protected] (209) 526-7617 Project Value: $60 Million+
Professional Fees: $900,000

IEC PROJECT EXPERIENCE

Haynes Generating Station Retrofit
Client: Los Angeles Department of Water & Power (LADWP) (via PB Power)

IEC Corporation provided services to LADWP as a
subcontractor for PB Power, Inc. under its contract to
provide Owners Representative Services for the
Haynes Generating Station Repowering Project (500
MW). PB Power solicited the services of IEC
Corporation to provide site construction coordinating
services, which included the oversight of the job site
during construction including such functions as:

Quality Assurance, site safety, monitoring the
contractor’s schedule and progress, validating and/or
approving invoices, environmental compliance, material receiving inspections, contract compliance, plant utility interfaces, design review, reviewing and resolving of Requests for Information (RFIs) and Engineering Change Notices (ECNs) to support the owner at the project site.

IEC PROJECT EXPERIENCE

Plant Engineering & Design
Client: Redding Electric

IEC provided the City of Redding with engineering and design services to support upgrade projects for its Unit 5 and Unit 6 gas turbine generators. IEC engineers provided on -call services and technical engineering support for mechanical, electrical, civil/stru ctural, instrumentation & controls needs.

ENGINEERING TASKS
• Design packages
• Project communications and
reporting
• Consulting services
• Site support
• Quality control engineering
• Contractor interface
• Project controls
Project Reference: Tom Cline, [email protected], 530-245-7034

IEC PROJECT EXPERIENCE

Fresno Peaker Facility
Client: Fresno Cogeneration Partners

IEC provided project and design engineering for the Fresno Peaker Facility exhaust duct upgrade involving an FT -4 Power Pac Combustion Turbine Generator. The original vertical exhaust discharge was changed into a side discharge configuration to allow for the new CO and SCR equipped exhaust duct. The project included the design and installation of a complete ammonia storage and forwarding system to support the new SCR equipment.

IEC also designed the transition ducting to mitigate thermal expansion loads on the turbine exhaust elbow as well as to provide an airtight seal for fire protection equipment operation. The PLC - based control system was modified to include the control of the SCR equipment and the Data Acquisition System (DAS).

ENGINEERING TASKS
• Design
• Site Support
• Project communications and
reporting
• Constructability review
• Quality control engineering
• Closeout and turnover
• Document control
• Project controls

IEC PROJECT EXPERIENCE

Cosumnes Power Plant Project
Client: Sacramento Municipal Utility District

The Cosumnes Power Plant is a 500 MW power plant located on a 30-acre site a half -mile south of the now closed Rancho Seco Plant in southeastern Sacramento County.

IEC provide d a wide range of eng ineering services and project management tasks for the power plant and natural gas pipeline project. The work began as a small contract and quickly expanded into a multiple-year commitment for project management, owner’s engineering, Chief Building Official services, and construction management services. IEC provided the licensing project manager, environmental specialist, structural, mechanical and electrical engineers, and a variety of subcontractor specialties, such as geotechnical services and pipeline inspection services. IEC also coordinated licensing, environmental documentation, mitigation planning, and the preliminary engineering layout for the plant, switchyard, and linear facilities.

IEC provided an electrical/controls field engineer to support construction and start-up activities for the plant. IEC’s field engineer reviewed designs, supervised electrical installation, managed electrical subcontractors, provided technical guidance, and coordinated work with other disciplines. Services also included working with the plant quality control team to ensure compliance with the latest electrical codes, specifications, permit conditions, and accepted practices. IEC’s field engineer supervised the installation of plant telecommunications equipment, including the interface with SBC and managed the installation and commissioning of SMUD’s Remote Terminal Unit, including loop

ENGINEERING TASKS
• Day-to-day operations
• Safety & regulatory compliance
• Outside services contracts
• Permitting
• Design Packages
• Project communications and
reporting
• Management briefings
• Cash flow projections
• Change orders
• Project performance evaluations
• SMUD contracts and standards
evaluation
• Agency approvals
• Cost estimates
• Budget reviews
• Scheduling and progress reporting
• Submittal management
• Constructability review
• Risk management
• Quality control engineering
• Closeout and turnover
• Document control
• SMUD interface
• SMUD representation
• Project controls

IEC PROJECT EXPERIENCE

check out and diagnostic review of communication links.

IEC’s field engineer also assisted startup lead contractor with commissioning activities throughout the facility as electrical systems were brought on line.

IEC managed subcontractors, provided technical
guidance and leadership to craft labor, managed project priorities and schedule, and coordinated work with other disciplines. Our personnel worked with the CPP quality control team to ensure compliance with the latest codes, specifications, permit conditions, and accepted practices. IEC personnel also assisted the startup lead contractor with commissioning activities throughout the facility as systems were brought online. IEC provided more than 50 people to support this contract, including in -house staff, contract employees, and subcontractors . The numerous assigned tasks were a direct result of IEC’s commitment to providing the best people for the job, both IEC employees and specialty subcontractors alike.

CPP Work Authorizations: Work Authorizations, in order of assignment, included 30-plus tasks:
• Cosumnes Licensing and Engineering
• SCA Peaker Project I&C Work
• Engineering Design to Modify Morrison Creek
Cross-Tie Station
• Construction Services RFQ Development
• Cultural Resource Remote Sensing Geophysical
Survey
• CBO Review Support
• Document Control
• Assistance with Permit Drawings
• Fire Protection Engineering
• Design and Drafting for Pipeline Extension
• CEC Compliance and CBO Document Control
Support
• Gas Pipeline Inspection
• Quality Assurance Support
• Construction Engineering Services
• Licensing and Compliance Project
Management
• Team Development & Right-of-Way
Verification
• Team Development & Safety Program
• Worker Environmental Awareness Training
Video Production
• Special Inspection, Testing, and Laboratory
Services
• Development of Gas Pipeline Pigging RFP
• Surveying Services and Development of Base
Map
• Development of Environmental Drawings
• Gas Pipeline Resident Engineer
• Inspector Training
• Construction Superintendent (Chief Inspector)
• Pre-Construction Surveying Support
• Gas Pipeline Inspection
• Contract Administration Support Services
• Field Electrical Engineer
• CBO Review Support Services
• Gas Pipeline Submittal Verification
Coordinator
• Water Supply Integrity Evaluation
• Piping & Support Design Analysis

Project Reference:

Kevin Hudson,
[email protected]
(916) 732-7101
Project Value: $500 Million+
Professional Fees: $5 Million

IEC PROJECT EXPERIENCE

McClellan Peaker Project
Client: Sacramento Municipal Utility District

IEC Corporation provided owner’s engineering services from conceptual engineering through construction for the McClellan Retrofit Project. This included project engineering, project management support, field engineering, and construction management services. The 80 MW GE 7EA Peaker Plant, owned and operated by SMUD, is located on the former McClellan Air Force Base. The retrofit was performed to ensure the plant complied with California emissions requirements. To assist SMUD in moving the project to complet ion, IEC provided project and field engineering, construction management, contracts management, RFP
development, quality control, cost control, contractor negotiations, and other project management duties.

Part of our responsibilities also included developing project design criteria and detailed civil, mechanical and electrical specifications associated with the switchgear, power system stabilizer, fin fan coolers, exhaust duct system, inlet cooling system, SCR system, and continuous emissions monitoring equipment. Due to the tight specifications written by IEC, the Contractor was unable to avoid liability when an error was made on their part and the Contractor was forced to pay liquated damages to SMUD.

ENGINEERING TASKS
• Day-to-day operations
• Project plan
• Safety & regulatory compliance
• Site support
• Design packages
• Outside services contracts
• Project communications and
reporting
• Management briefings
• Cash flow projections
• Change orders
• Project performance evaluations
• SMUD contracts and standards
evaluation
• Agency approvals
• Cost estimates
• Budget reviews
• Scheduling and progress reporting
• Submittal management
• Constructability review
• Risk management
• Information management
• Quality control engineering
• Closeout and turnover
• Document control
• SMUD interface
• SMUD representation
• Project controls
Project Reference: Dick Wallace, Retired SMUD Manager
Project Value: $2 Million+
Professional Fees: $250,000

SECTION B

EXPERIENCE & REFERENCES

B.1-4

PROJECT EXPERIENCE

Mechanical Construction
Local Project List

Performance Mechanical. Inc. (PMI)
has built power plants for nearly three
decades. Our staff and crews are
experienced in being part of an EPC
Team, being the prime contractor, or
being a subcontractor. We have fully
erected units such as conventional
natural gas, combined cycle power to
alternative fuel, and alternative energy
power plants, including biodiesel,
landfill gas, and concentrated solar
projects. Major components and
systems installed by PMI include
natural gas turbine generators, steam turbine generators, heat recovery steam generators (HRSGs), air cooled condensers (ACCs), cooling towers, water systems, BOP piping and equipment, condensers, lube oil systems, structural steel erection, concrete foundations, and underground utilities.

The following pages include a list of 100+ projects performed by PMI for local companies, utilities, and agencies including EthosEnergy, NCPA, and City of Redding.

Performance Mechanical, Inc.

General Mechanical Contractor
Corporate Office, Pittsburg, CA | Sacramento | Gardena | 925.432.4080 | www.perfmech.com PMI Job History for References Provided
Job # Description Client Date
Started
92789 CPP Sidewalk Widening Ethos Energy 1/31/2020
94229 HRSG2 Drain Line Repair Ethos Energy 1/31/2020
94228 Pressure Test Diesel Line NCPA 1/28/2020
94219 Repair Desuperheater Nozzle Ethos Energy 1/27/2020 94127 Vapor Repair Ethos Energy 1/15/2020
94176 Demo Unit 2 & 3 ATU Line Ethos Energy 1/15/2020
94209 CCI Valve Work Support NCPA 12/31/2019
94213 McClellan Gearbox Inspection Ethos Energy 12/13/2019 94208 Emergency Impeller Repair Ethos Energy 11/30/2019 94195 SPA TriTool Machining Support Ethos Energy 11/12/2019 94189 SPA Duct Burner Pipeline Mods Ethos Energy 11/8/2019 94119 Oily Water Sump Pump Piping Ethos Energy 8/31/2019 94133 Pump House Transformer Swap Ethos Energy 8/31/2019 94122 6" Water Treatment Vent Ethos Energy 7/31/2019
94112 Tube Leak Repair Ethos Energy 7/26/2019
94088 Quality Weld Procedure Ethos Energy 6/27/2019
94104 ZLD Condenser Crack Repair Ethos Energy 6/21/2019 94117 CPP Shaft Guard Mods Ethos Energy 6/21/2019
94103 U3 HRH Loop Emergency Repair Ethos Energy 6/19/2019 94105 U3 Preheater Tube Leak Ethos Energy 5/31/2019
94094 SPA Shaft Guard Window Mods Ethos Energy 5/22/2019 94096 SPA Fuel Gas Valve & Piping Ethos Energy 5/22/2019 94073 Repair Crack Unit 2 RH Ethos Energy 3/31/2019
94081 Emergency RH Loop Leak Ethos Energy 3/27/2019
92688 Unit 2 FG Shutoff Valve Ethos Energy 2/28/2019
94046 Buff 10" Welds for NDE Ethos Energy 2/25/2019
94047 Repair Cracked Valve Weld ZLD Ethos Energy 2/20/2019 94057 Replace Gauge PI-3306 Ethos Energy 2/14/2019
94059 U2 Compressor Air Valves Ethos Energy 2/10/2019
94060 Replace Two CCW Ethos Energy 2/9/2019
94053 Remove Additional CW Elbow Ethos Energy 2/9/2019
94056 Replace LPS Valve 3029 Ethos Energy 2/7/2019
94052 HP Steam Warm Up Drains Ethos Energy 2/2/2019
92677 CPP Perf. Heater Replace Ethos Energy 1/31/2019
94038 Remove CCW Elbow for Repair Ethos Energy 1/31/2019 94009 Two BFW Bypass Lines Ethos Energy 12/31/2018
93486 Repairs Steam Leaks City of Redding 11/30/2018
93493 Fab & Install Ladder Cage Ethos Energy 11/30/2018 94018 McClellan Shaft Guards Ethos Energy 11/17/2018
93460 Modify BFW Pump Seal Ethos Energy 10/31/2018
94008 Replace Leaking FG Drain Valve Ethos Energy 10/31/2018

Performance Mechanical, Inc.

General Mechanical Contractor
Corporate Office, Pittsburg, CA | Sacramento | Gardena | 925.432.4080 | www.perfmech.com 93474 Cooling Tower 2" Sensor Mods Ethos Energy 8/27/2018 93480 HP Bypass Weld Buffing Ethos Energy 8/15/2018
93459 Repair Cracked Distillate Line Ethos Energy 7/31/2018 93414 Assist CCI Valve Rework NCPA 6/30/2018
93400 U9 Penstock Repairs City of Redding 6/29/2018
93410 Repair Pressure Gauge Tee Ethos Energy 6/27/2018
93453 Repair BFWP Unions Ethos Energy 6/23/2018
93454 MOV Handrail Mods Ethos Energy 6/20/2018
93403 Repair Pipe Shoe Leak BR002 NCPA 6/20/2018
93404 Replace Mag Ox NCPA 6/18/2018
93407 HP Separator Leak I.D. NCPA 6/17/2018
93405 Replace F91 Valve NCPA 6/15/2018
93406 Add Flanges NCPA 6/8/2018
93423 V-3024 Equalizing Line Ethos Energy 5/29/2018
93429 ZLD Repairs Ethos Energy 5/23/2018
93441 Replace MOV 1040 Ethos Energy 5/23/2018
93416 Repair Liner Plates & Insul NCPA 4/30/2018
93419 Adjust Baffle Plates NCPA 4/30/2018
94092 (SVP) April'19 Outage NCPA 4/25/2018
93409 Repair Spring Hangers Ethos Energy 4/22/2018
93246 GE Fuel Gas Shutoff Valve Ethos Energy 4/20/2018
93430 Relocate Condensate Quill Ethos Energy 4/16/2018
93436 Replace Valve Equalizing Lines Ethos Energy 4/16/2018 93395 P.M.I. Equalizing Lines Ethos Energy 4/12/2018
93417 Repair Tube Support Channel NCPA 4/10/2018
93247 Buff Welds for NDE Ethos Energy 4/10/2018
93418 Fix Broken Angle Iron NCPA 4/7/2018
93425 Blowdown Valve Ethos Energy 4/2/2018
94083 LEC OUTAGE NCPA 4/2/2018
93433 Replace Leaking Valves Ethos Energy 3/30/2018
93386 Repair Steam Leaks City of Redding 1/31/2018
93358 Water Treatment Eye Wash Ethos Energy 1/29/2018
93349 Aux Gearbox Inspection Ethos Energy 12/21/2017
93366 Replace BD Tank Drain Valve Ethos Energy 11/30/2017 93376 Unit 2 Performance Heater Ethos Energy 11/27/2017 93377 Move-2100 Crack Repair Ethos Energy 11/19/2017
93367 LP and IP Drain Valves Ethos Energy 11/19/2017
93369 Seal Water Glass Ethos Energy 11/18/2017
93368 Water Treatment 4" Cleanout Ethos Energy 11/15/2017 93348 Unit 2 LP Section Tube Leak Ethos Energy 11/1/2017 93318 Welding Support 7-8 Ethos Energy 8/10/2017
93317 Install Pressure Gauges Ethos Energy 8/3/2017
93281 HP Evaporator Tube Repair NCPA 6/29/2017
93255 Attemperators Replacement Ethos Energy 6/29/2017

Performance Mechanical, Inc.

General Mechanical Contractor
Corporate Office, Pittsburg, CA | Sacramento | Gardena | 925.432.4080 | www.perfmech.com 93262 Replace HP Drum Manways Ethos Energy 6/29/2017
93287 Clarifier Outlet Modifications NCPA 6/23/2017
93288 Support CCI for Valve Demo NCPA 6/22/2017
93289 Aux BFW Pump Piping NCPA 6/20/2017
93290 P91 HP Steam Valve NCPA 6/17/2017
93292 Relief Valve Demo Replace NCPA 6/17/2017
93284 CT Bleed Pipe Outer Ring NCPA 6/12/2017
93291 LP Condensate Valve NCPA 6/12/2017
93275 ZLD Welding Support Ethos Energy 6/10/2017
93258 Fuel Gas Block Valves Ethos Energy 6/8/2017
93270 Remove 20" Tee Ethos Energy 6/8/2017
93285 Main & Pilot Vent Extension NCPA 6/7/2017
93280 U3 LP Tube Leak Ethos Energy 6/7/2017
93282 Lodi, Reheater #3 Support NCPA 6/5/2017
93283 HRSG Baffle Repair NCPA 6/6/2017
93286 HRSG Hot Spot Repairs NCPA 6/5/2017
93293 LEC IP RAC Olet NCPA 6/5/2017
93260 HRSG Floor Repairs Ethos Energy 6/5/2017
93261 Outage NDE Scope Ethos Energy 6/2/2017
93271 Replace 20" Flanged Tee Ethos Energy 6/2/2017
93274 ZLD Brine Pup Ethos Energy 6/1/2017
93272 Oily Water Separator Piping Ethos Energy 6/1/2017 93294 Evaporator Repair Ethos Energy 6/1/2017
93302 Unit 3 Tube Leak 5-26-17 Ethos Energy 5/27/2017
93201 CT1 Secondary Containment NCPA 5/24/2017
93259 Spring Hanger Outage Work Ethos Energy 5/5/2017
93241 PCV-3021 Replacement Ethos Energy 4/3/2017
93250 AuxCoolingWaterLeak Repairs Ethos Energy 4/3/2017 93244 Repair Shell Leak Ethos Energy 3/2/2017
93224 Potable Water Lab Eyewash Ethos Energy 2/6/2017
93225 December Clarifier A Repair NCPA 2/3/2017
93220 Aux Gearbox Inspection Ethos Energy 12/20/2016
93216 Install Vacuum Pump B NCPA 12/8/2016
93211 Install NH3 Flanges NCPA 12/6/2016
93217 November Clarifier Repairs NCPA 12/6/2016
93213 Ladder Cage Modifications Ethos Energy 12/1/2016
93209 U9 Trash Screen Repairs City of Redding 12/2/2016 93207 Emergency Weld Repair Ethos Energy 11/2/2016
93204 Repair Clarifier & Drain Leaks NCPA 10/20/2016
93205 Oct Clarifier Leak Repairs NCPA 10/20/2016

IEC PROJECT EXPERIENCE

Almond 2 Power Plant (A2PP)
Client: Turlock Irrigation District

PMI was the General Contractor on the
Construction of a Natural Gas -Fired Simple
Cycle Peaking Facility rated at gross
generating capacity of 174 MW with three
General Electric LM6000PG Turbines with
SPRINT (SPRay INTercooling) and associated
support equipment including an 115 kV
Switch Yard. Implementation of CEC Staff Assessment compliance programs during construction:

Biological, Cultural, Storm Water Pollution Prevention and Air Quality programs. Excavation of 6,071 cy of soil, back filled 2,500 cy of soil, installation of 1,500 tons of asphalt for Almond 2, new storm water drain system, modification of Winco yard storm water retention pond and construction of new storm water retention pond for Almond 1 and Almond 2 power plants.
• Concrete: 3,114 cy for Equipment Foundations and misc. pads & footings • Architectural: 3,150 square feet expansion of existing warehouse and shop • Fence: 2,730 lineal feet of new permanent fence and 2,137 lineal feet installation and removal of temporary fence and demolition of 1,896 lineal ft of existing fence. • Piping: 21,481 ft. of underground piping, 6,267 ft. of above ground piping, lube oil flushing, gas lines air blows with targets, hydro and pneumatic testing. • Tie Ins: Installed a total of 40 tie ins to interconnect new Almond 2 plant with existing plant during shut down with no impact to Almond 1 plant operations.
• 115kV Switch Yard Installation: Installation of substation control house, breakers, transformers, structural, cabling and testing.
• Electrical: Installation of underground electrical duct banks, new grounding grid, cathodic protection, above ground electrical and instrumentation installation, calibration and testing including GE equipment. Interconnecting of new system to Almond 1 existing control centers, plus ADT plant security system and lighting.
• GE LM600 CTG: Installation of three GE LM600 0 natural gas combustion turbine generator packages and supporting equipment.
• SCR Erection: Erection of three Selective Catalytic Reduction units and Catalyst Loading after first fire, including electrical and instrumentation, calibration and testing.

IEC PROJECT EXPERIENCE

Rodeo Refinery Renewed
Client: Phillips 66

VALUE DELIVERED
Performance Mechanical Inc. (PMI) helped convert Phillips 66’s San Francisco refinery into a site for renewable fuel production. PMI provided turnkey solutions for the project, overcoming a compressed schedule, congested work site, and inclement weather. Before the project, the refinery produced 120,000 barrels of gasoline per day, and now it will produce 680 million gallons of renewable diesel, renewable gasoline, and sustainable aviation fuel per year.

SOLUTIONS
PMI provided construction planning, staffing, supervision, fabrication, logistics, and installation services for pre-outage work. This included major equipment setting, piping, rotating equipment, and civil work over different units located throughout the refinery. The refinery facility is in Rodeo, CA. The project duration was 20 months.

In total, PMI installed the following:
• 27,465 linear feet of pipe, including supports and testing • 115 tons of structural steel
• 26 pieces of equipment, including offloading, rigging, and setting • 134 pipe tie-ins

CLIENT BACKGROUND
Phillips 66 is a diversified energy manufacturing and logistics company with unique businesses in refining, midstream, chemicals, and marketing/specialties.

CLIENT OBJECTIVES
Phillips wanted a cutting-edge site to refine and provide renewable fuels using waste oils, fats, greases, and vegetable oils as feedstock.

IEC PROJECT EXPERIENCE

Solar Energy Project, Riverside County, CA
Client: Genesis Solar

VALUE DELIVERED
PMI provided mechanical equipment and pipe installation services for this concentrated solar power station located in the Mojave Desert. The station features two separate 125 -MW solar generating units that utilize advanced solar trough technology. For the first unit, PMI completed 5,978 welds, with 324 of them tested and only four rejected for a 1.23 percent rejection rate. Then, for the second unit, PMI completed 6,006 welds with a zero-percent rejection rate after 398 tests. Altogether, 750,000 labor hours went into the project, spanning 21 months.

CLIENT OBJECTIVES
The client required a contractor with the capacity for this large-scale project and familiarity with solar power stations.

SOLUTIONS
We installed a wide range of mechanical equipment and piping systems, including:

• Balance of plant piping on both units
o Carbon steel, stainless steel, alloy, and galvanized materials o 50,000 feet of pipe installed for Unit 1
o 67,000 feet of pipe installed for Unit 2
o All pipe supports
• Structural steel
• Anchors and grouting
• Rotating equipment
• Exchangers
• Tanks
• Vessels
• Auxiliary boilers
• Fin fans
• Power distribution center

CLIENT BACKGROUND
Genesis Solar is one of the world’s largest producers of solar energy.

IEC PROJECT EXPERIENCE

Brea Olinda Power II Facility
Client: Olinda Alpha Landfill

VALUE DELIVERED
For the new Brea Olinda Power II facility,
Performance Mechanical, Inc. (PMI) installed
mechanical equipment and piping designed to
capture landfill gas from decaying trash to use
as fuel for combustion turbines. Our solutions
helped remove harmful contaminants in the
gas, to allow for clean methane production.

CLIENT OBJECTIVES
The client needed full-service installation of mechanical equipment and piping to support their methane gas recovery system.

SOLUTIONS
Located at the Olinda Alpha Landfill, the Brea Olinda Power II project was comprised of two areas: gas collection/conditioning (GCC), and power block.

PMI installed mechanical equipment in the GCC area that was designed to chill and compress the captured methane gas before being used as fuel for the combustion turbines. In the power block area, PMI installed:

• Four Solar® Taurus 60 combustion turbine generators
• Two cooling towers
• Steam turbine generators
• Four heat-recovery steam generator units and associated • pumps/equipment/piping

CLIENT BACKGROUND
Opened in 1960, the Olinda Alpha Landfill is a Class III site with 453 acres permitted for refuse disposal, and an average disposal rate of nearly 7,000 tons per day. Olinda was one of the first sites in the U.S. to construct a landfill-to-gas energy plant, powering 3,000 homes at the time.

IEC PROJECT EXPERIENCE

BOP, STG & AG Electrical + HRSG and ACC Erection
for GWF Tracy Combined Cycle Power Plant
Client: GWF Power Systems

Perform BOP and electrical for the 315 MW GWF Tracy combined cycle power plant. Scopes include installation an Alstom steam turbine and generator, installation of balance of plant equipment, large bore heavy wall chrome and carbon steel piping, fabrication and installation of small-bore piping, misc. equipment (i.e. BFW pumps, condensate pumps, etc.), erect STG enclosure. Coordination with major subcontractors (Electrical, insulation, painting, scaffold, heavy rigging and cranes). Work includes approximately 5,600 feet of large bore pipe, 4 ,800 feet of small-bore pipe, 3 ,811 diameter inches of shop fabrication and 319 tons of structural steel. Electrical and insulation subcontracts were added to scope during the project.

Erect 2 Alstom HRSGs for the 315 MW GWF Tracy combined cycle power plant. Scope includes installation of the large bore heavy wall carbon steel and 9Chrome pipe, fabricate and install the small-bore carbon steel and chrome pipe, and dismantling of the existing stack, SCR, tempering fans and a portion of the exhaust duct work . Work includes approximately 5,922 feet of large bore pipe, 10,112 feet of small-bore pipe, 7,254 diameter inches of shop fabrication and 103 tons of structural steel.

Field erection of 25 cell air cooled condenser and turbine exhaust duct. Work includes approximately 3 ,042 feet of large bore pipe, 1,320 feet of small-bore pipe, 1,424 tons of structural steel, 107 tons of platforms, and 170 cubic feet of grout.

SECTION B

EXPERIENCE & REFERENCES

B.1-5

PROJECT EXPERIENCE

Electrical Construction
Local Projects
Client: City of Roseville, Ethos Energy, PG&E, Siemens, SMUD

Placer Electric has a vast experience working on industrial sites and Power Plants. Over the years , Placer Electric has worked on PG&E, SMUD and City of Roseville sites. PEI has completed a multitude of service projects at the Roseville Energy Park and ha s a current service agreement with the City of Roseville. Recently, Placer Electric provided support to REP on completing an unfinished project by relocating existing fiber communication runs around the existing site . PEI also provided Siemens electrical support in replacing a generator back in 201 9. In 201 9, PEI completed a project for the Colusa Generating Station where a new heat blanket system was installed. The system consisted of a new electrical distribution and required running large circuits through the existing cable tray system to provide all necessary circuits for this project.

PEI has also worked for ETHOS Energy who manages the SMUD SPA Cogen III plant in South Sacramento and completed all the rework to install the new fire pump system and building at that site.

Overall Placer Electric has staff that is familiar with Industrial/ Power generating sites and are well versed in the safety and PPE protocols required when working at these facilities.

Below is a list of tasks performed for the City of Roseville at the Roseville Energy Park:

No. Task Date Description
1 Relocate Fiber
Cans to Adjacent
Panels
October 2018
Provide labor and material to relocate fiber trunk lines and splice box into the adjacent cabinet. This includes mounting the fiber splice can, reconnection of the fiber cables to the fiber box, replacing chewed up fiber
connections and adding new connectors, and
performing tests on the fiber.
2 Conduit and
Cabling for New
AVR
April 2018
Provide all labor and material for installing cables and conduit from the existing cabinet to the new AVR, based on Siemens drawings. Also, install two (2) 60A 2-pole DC breakers without running cable or conduit to them.

PROJECT EXPERIENCE

3 Re-Install
Generator March 2018
Provide all labor and material to reinstall any electrical apparatuses such as conduit and cabling, electrically
terminate any existing cable and wire, bolt any busses
that need to be reinstalled, and label all conductors that were terminated.
4 Removing
Electrical
Components from
Generator
August 2017
Provide all labor and material to remove any electrical apparatuses (conduit, cable, bussing) from the
generator, and label all conductors to be removed for
ease of re-installation.
5 Wire Upgrade for
Existing Site
Lighting
September 2016
Provide all labor and material for pulling out existing wire from poles and installing ~5000' of wire between
electrical boxes, poles, and the lighting panel.
6 DCS Upgrade February 2016
Provide all labor and materials for determinating and
reterminating 4,828 wires for the Siemens DCS upgrade.

Also provide and install fiber optic cable and modbus
cable runs from the control room to the cabinets
1CJP10, 1CJP20, 1CHA10, 1CHA20, 2CJP10, 2CJP20,
2CHA10, and 2CHA20.
7 Temporary Power
Receptacles September 2014
Provide all labor and materials for installing four (4) 50A temporary power receptacles and associated 2-pole
breakers. Boxes are installed adjacent to panels feeding them.
8 Heat Tracing December 2013
Zero Liquid Discharge (ZLD) Area
Provide labor and material to remove existing six (6)
cables from the wrong panel in the MCC and the devices
in the field; remove existing six (6) breakers in that
panel, pull and terminate existing cables that are coiled up on cable tray to the devices in the field; and install chases needed from the existing junction box to existing heat trace panel and pull in existing cables and
terminate to the breakers we reinstalled from the other panel.

Steam Turbine Area
Provide labor and material to install three (3) new heat tracing circuits in the steam turbine area, including
conduit installation, junction boxes, and heat tracing
cable as needed.
9 4160V Conduit
Repairs April 2013 Repair PVC flex conduit connections between PVC hard conduit and motor head pecker at two motor locations
10 Boiler Feed Pump
1B & 2B
Relocation
November 2010
Provide labor, material, and supervision for temporary
relocation of all associated wiring for the boiler feed pumps
11 Con Ex Power &
Lighting May 2010 Provide labor, material, and supervision for the installation of a Con Ex box.

PROJECT EXPERIENCE

12 Monument Sign
Lighting May 2010
Provide all labor, material, and supervision for installing two (2) ground mounted light fixtures for illuminating
the monument sign. New light fixtures are photocell
controlled. Conduit is routed underground to the
pullbox, into the building for power.
13 Power for Sump
Pump May 2010 Provide all labor, material, and supervision for installing a disconnecting means and hard wire to the sump pump.
14 Conduit and
Power to Trasar
Panel
April 2010 Provide all labor, material, and supervision for installation of conduit and cable to a new trasar panel. 15 Power to Nitrogen
Generator March 2010
Provide all labor, material, and supervision for installing a receptacle in the enclosure for the Nitrogen
Generator. Conduit run from the surface into the
enclosure is sealed and weatherproof.
16 Lighting to Lube
Oil Storage Shed March 2010
Provide all labor, material, and supervision for installing new lighting and reconnecting existing lighting at the
lube oil storage shed. New conduit for this project is run underground.
17 Added Lighting at
UF Addition Cover January 2010
Provide all labor, material, and supervision for installing one (1) new 8' fluorescent light fixture. The new light is tied into the existing lighting circuit and is mounted to the new UF addition covered structure.
18 Added Lighting
and Grounding
Re-Route
August 2009
Provide all labor, material, and supervision for installing one (1) new wall pack light fixture, and to reroute the grounding that is a trip hazard in the steam turbine lube oil filtration area.
19 Lube Oil Shelter
Lights &
Receptacles
August 2009
Provide labor, material, and supervision for the
installation of three (3) new light fixtures, four (4) new convenience receptacles, and grounding for the new
structure. Provide electrical design drawings.
20 Miscellaneous
Lighting March 2009
Provide labor, materials, and supervision for the
installation of eight (8) light fixtures. Submittals are provided for approval prior to ordering and installation.

Lighting is tied to the lighting control system at REP. 21 Camera Cables October 2008
Provide all labor and supervision for the installation of all necessary cables for a total of six (6) cameras. Three (3) of the cameras are located on a pole at the Northeast corner of the site, and the other three (3) are on a pole by the main gate.

SECTION B

EXPERIENCE & REFERENCES

B.1-6

PROJECT EXPERIENCE

Bayview
Mountain View, CA
• Design Build GMP
• $22 Million, 1,695,000sf
• 3 Building project connected by an
underground parking garage. Fully covered by
automatic wet sprinkler system and fire pump.

UC Merced Expansion
Merced, CA
• Design Build
• 13 building campus expansion including
student housing, classrooms and
laboratories.

Livermore Oaks
Livermore, CA
• Design Build
• New automatic fire sprinkler in 3 building
totaling 1,450,000 sf
Travis AFB C-17 Hangar
Fairfield, CA
• Design Build
• Fully sprinklered
• 8 - Foam Systems
• Fire Pump

PROJECT EXPERIENCE

Westfield Valley Fair Mall
Addition and New Parking
Structure
San Jose, CA
• Lump Sum
• $5.8 Million
• Fully sprinklered 5 -story parking
garage with escalator/stair system.

New 2 story mall shop addition.

Automatic wet standpipes and a fire
pump. AHJ City of San Jose
SFO-11 Data Center
Hayward CA
• Lump sum
• $1.6 Million
• 2 story data center shell with 3
phases of data room build out.

Includes multiple pre -action
systems for a NDA client.
• AHJ Hayward Fire Department

Sacramento Convention Center
Renovation
Sacramento, CA
• Lump Sum
• $3.4 Million
Tear down and rebuild of the Ballroom Area
and modifications to the existing system.

Multiple standpipes and risers tying into
the existing dual fire water supply. AHJ City
of Sacramento
Lemoore Naval Air Station
Lemoore, CA
• Lump sum
• $250 Thousand
• Complete gut and new install of
Buildings 960 and 961 Naval Training
buildings.
• AHJ NAVFAC

PROJECT EXPERIENCE

California State University
Sacramento Union Hall
Renovation
• Lump Sum
• $2.2 Million
• Addition and renovation of the
existing multi-story Union Hall with
new wet sprinkler systems, anti -
freeze and window sprinklers. New
fire pump. AHJ CA State Fire Marshal

Civil Engineer Operations and
Administration Building
Beale AFB, CA
• Lump sum
• $278 Thousand
• Replacement building for the CEA
Operations Facility. New wet sprinkler
system.
• AHJ Army Corps of Engineers
Genentech Employee Centre
South San Francisco, CA
• Design Build
• 5 Story building fully
covered by overhead wet
sprinkler system with
manual wet standpipe in
stairwells.

San Francisco General Hospital
San Francisco, CA
• Design Build GMP
• $12.8 Million, 800,000 sf
• Fully sprinklered new building with
manual wet standpipes and pump.
• OSHPD, Level 1, and Big Room
Project

PROJECT EXPERIENCE

Kaiser Capitol Gateway Medical
Office Building
• Sacramento, CA
• Design Build GMP
• $2.1 Million
• 400,000sf
• Fully sprinklered 6-story medical
office building with 3 stories parking
and a penthouse Manual wet
standpipes and a Diesel fire pump.

AHJ Sac City FD
Kaiser Vallejo
• Design Build
• Redesign of the existing system in
active hospital and CUP Building
• OSHPD Project
OSHPD Service and Tenant
Improvement Various Campuses, Northern
California
• Fire Sprinkler Service and repairs in
various hospital campuses and
medical office buildings.
•
PG&E RAS Pre-con Building
Rocklin, CA
• Lump Sum
• $290,000
• 72,700sf
• Fully sprinklered 1-story server building
with wet and multiple pre-action systems
zoned for each server room. AHJ Placer
County FD

PROJECT EXPERIENCE

SMF Airport Ticketing Southwest

ATO & OPS
• Lump Sum
• $120,000
• Remodel the existing Southwest
ATO & Operations areas fire
sprinklers for new ceilings.
• Secured Areas, System Shutdown,
Fire Pumps and safe offs.

McKesson Rack Storage
Replacement System
• Lump Sum
• $676,000
• Replacement of (14) 200lf storage
rack sprinklers. Fire Pump. AHJ West
Sacramento FD
Intel FM SPGC Improvement
Folsom Campus
• Lump Sum
• $171,000
• Remodel of an existing command
control center to accommodate a
new server room.
10th & O St Office Building,
Sacramento
• Design Build GMP
• $4.8 Million, 481,000sf
• 11 Story Office Building with 2
levels of parking and a penthouse.

Vertical turbine fire pumps
supplying automatic Standpipe, fire
sprinkler and pre-action systems
throughout. And NOVEC 1230 clean
agent systems. AHJ SFM.

SECTION B

EXPERIENCE & REFERENCES

B.1-7

PROJECT EXPERIENCE

Turnkey Frame 7 DCS Upgrade
Jack County 620MW Unit 1
Client: Brazos Electric Co-op

Jack County Unit 1 is a power plant owned and operated by Brazos Electric Power Co -op, Waco, Texas. The plant is a 2x1 650MW combined cycle with GE Frame 7FA CTGs.

Brazos Electric Co -op selected Verve Industrial Protection on a turnkey EPC (Engineering, procurement &
construction) basis to upgrade the existing plant’s DCS from Delta-V to Ovation. Verve’s scope included project
management, procurement of h ardware/software from
DCS/PLC vendors, preparation of panel layouts and
assembly drawings for panel manufacturer use, and
detailed design and engineering including electrical
design, schematics, wiring termination drawings, logic
programming and graphics. Verve also performed
demolition of existing control cabinets and installation of new cabinets and rewiring. After construction, Verve
performed I/O checkout, startup, testing and
commissioning, tuning of combustion controls and closed loop process systems. Verve also developed operator
training documents for providing necessary training to cover multiple shifts. Upon successful startup and commissioning, the engineering team incorporated all the redlines a nd updated any affected drawings and documents with the changes/modifications carried out on site and issued as -built documentation in both native and PDF format.

ENGINEERING TASKS
• Detailed electrical design
• Prepared panel layouts and assembly
drawings for panel manufacture use
• Electrical drawing package including
schematics, wiring termination drawings,
logic programming and graphics
• Demolition/installation of control cabinets
• Startup, testing, and commissioning
• System training

PROJECT EXPERIENCE

Electrical Design for Frame 7 BOP Controls
Neenah
Client: Alliant Energy

Neenah is a 3 72 MW natural gas -fired power plant owned by Alliant Energy. The plant has two (2) Frame 7EA Simple- Cycle Gas Turbines. Alliant Energy selected Verve Industrial to perform the electrical design of the BOP controls
migration from GE9030 to Emerson Ovation.

To complete this scope of work, Verve Electrical Engineers performed on site visits to verify existing conditions of the site. With accurate documentation of the facility, Verve was able to prepare a construction package that included demolition drawings, wiring and termination drawings,
network drawings, panel layout drawings, and a cable
schedule.

ENGINEERING TASKS
• Electrical Design
• As-Built existing facility conditions
• Developed detailed construction package

PROJECT EXPERIENCE

Electrical Design for STG Controls
Riverside
Client: Alliant Energy

Riverside is a 603MW combined cycle natural gas plant , owned by Alliant Energy. Alliant Energy selected Verve
Industrial Protection to perform the electrical design of the STG controls migration from Siemens TXP to Emerson’s
Ovation.

To complete this scope of work, Verve Electrical Engineers performed on site visits to verify existing conditions of the site. With accurate documentation of the facility, Verve was able to prepare a construction package that included
demolition drawings, wiring and termination drawings,
network drawings, panel layout drawings, and a cable
schedule.

ENGINEERING TASKS
• Electrical Design
• As-built existing facility conditions
• Developed detailed construction package

PROJECT EXPERIENCE

Electrical Design for BOP Controls
Sheboygan Falls
Client: Alliant Energy

Sheboygan Falls is a 3 80 MW natural gas power plant
owned by Alliant Energy. The plant has two (2) Frame 7EA Simple-Cycle Gas Turbines. Alliant Energy selected Verve Industrial to perform the electrical design of the BOP
controls migration from GE9030 to Emerson Ovation.

To complete this scope of work, Verve Electrical Engineers performed on site visits to verify existing conditions of the site. With accurate documentation of the facility, Verv e was able to prepare a construction package that included demolition drawings, wiring and termination drawings,
network drawings, panel layout drawings, and a cable
schedule.

ENGINEERING TASKS
• Electrical Design
• As-built Existing facility conditions
• Developed detailed construction package

SECTION B

EXPERIENCE & REFERENCES

B.1-8

PROJECT EXPERIENCE

Meadows Energy Storage, Placer County, CA

R.E.Y . Engineers, Inc. provided comprehensive engineering and land surveying services for the Meadows Site in Roseville, California, including the development of conceptual and civil entitlement plans. Initially, R.E.Y . coordinated with ECORP , Ormat, and other consultants to create a conceptual site plan that adhered to client specifications and City requirements. R.E.Y . services included boundary resolution, topographic mapping, drafting conceptual utility, grading, and drainage plans based on the approved site plan and City standards.

R.E.Y . also assisted with preparing the
civil entitlement package for submission
to the City of Roseville Planning
Division, updating the plans according
to city review comments. The scope
included preliminary stormwater
quality compliance, involving an in itial
evaluation of source control, runoff
reduction, and stormwater treatment
needs.

PROJECT EXPERIENCE

Valencia 1 – 3 Solar Energy Fields, Imperial County, CA

R.E.Y . provided engineering and surveying services for GL Renewable across three solar energy field projects in Imperial County, CA. Each project involved the development of solar energy infrastructure, including solar panel arrays, retention basins, transformers, inverters, transmission lines, and service roads.
▪ Valencia 1 Solar Energy Field: Located south of the City of Westmorland, this 17 -acre solar field was completed successfully with no design issues. R.E.Y .
collaborated with Imperial County and the City
of Westmorland to facilitate improvements
and establish City right -of-way, including
feasible entry points. R.E.Y . prepared and
processed the necessary grading and
improvement plan sets for the construction of
the solar field infrastructure.
▪ Valencia 2 Solar Energy Field: This 10 -acre
solar field, situated off Highway 111, required
design work for deceleration and acceleration
tapers to ensure access to the site’s entry
gates. R.E.Y . designed multiple retention
basins, calculated drain times, and evaluated the need for mosquito abatement measures. R.E.Y . was responsible for preparing and processing the grading and improvement plan sets needed for the solar facilities.
▪ Valencia 3 Solar Energy Field: Spanning 19 acres, this solar field is located adjacent to two County roads and bounded by County irrigation canals. R.E.Y . worked with GL Renewables to refine the site layout, optimizing the placement of retention basins and site grading to balance the s ite using on- site spoils. R.E.Y . prepared and processed the required grading and improvement plan sets.

Overall, R.E.Y . played a critical role in the successful planning and execution of these solar energy projects, ensuring that all required infrastructure and design elements were efficiently handled.

SECTION B

EXPERIENCE & REFERENCES

B.1-9

AAAAAAAAAAAAAA
Youngdahl Consulting Group, Inc. has performed multiple geotechnical engineering and geohazards studies and all special inspection and testing services for the new California ISO building in Folsom, California. Cal ISO is a not -for-profit public-benefit co rporation charged with operating the
majority of California’s high -voltage wholesale power grid servicing more than 30 million consumers.

Youngdahl completed environmental engineering,
geotechnical engineering and geologic hazards evaluations for various phases of project design and development.

Our studies have included detailed geotechnical and
geophysical investigations for site characterization. Both surfical and down -hole geophysical studies were performed to evaluate rippability of the underlying bedrock materials and to optimize the seismic design criteria for design of this critical structure.

Since the site had been impacted by historic mining activities, both by gold dredging and hard rock mining, detailed
historical research and subsurface exploration was
performed. An evaluation for the presence of contaminants relating to former mining activities was performed as well as an assessment for naturally occurring asbestos.

Construction of the critical service structures was recently completed and Youngdahl continued our engineering services by providing complete earthwork, special inspection and materials testing observation and testing services during project construction. Our full range of capabilities has provided one stop shopping support for the project
minimizing construction scheduling delays and enabling
timely response to unanticipated field conditions.

Cal ISO
Folsom, California
Client: Dreyfuss and Blackford
Architecture
Contact: Gus Fischer
[email protected]
(916) 453-1234
Project Cost: $158 Million
Cost of Services: $382,630.00
Key Elements
▪ Detailed Geotechnical Studies
▪ Geophysical Investigations
▪ Earthwork Observation and
Testing
▪ All Special Inspection
o Structural Concrete
o Shotcrete
o Pre-Cast Concrete
o Post-tensioned Concrete
o Masonry
o Structural Steel Welding
o Fireproofing
o Non-Destructive Testing
▪ Laboratory Materials Testing
(over 325 specimens)
▪ Rippability Evaluations
▪ Seismic Design Criteria
Optimization
▪ Naturally Occurring Asbestos
Assessments
▪ Historic Mining Contaminates
Evaluation

AAAAAAAAAAAAAA
Youngdahl Consulting Group, Inc. conducted a Geotechnical Engineering Study for the proposed relocation of the North City Substation which is owned and operated by the
Sacramento Municipal Utility District (SMUD). The substation was relocated to the termin us of 20th Street in Sacramento, California, between the Southern Pacific Railroad Tracks and the American River.

The existing substation experienced significant settlement due to the presence of loose fills and native soils. A detailed subsurface investigation was performed to assess the
subsurface conditions. The field exploration was conducted in conjunction with the environmental assessment to provide cost effective exploration for site development.

Youngdahl’s scope of services initially included the advancing of 26 exploratory borings at locations predetermined by SMUD’s subconsultant and was later expanded to address
burn waste found during the construction process.

Laboratory testing was performe d in our in -house materials testing laboratory to evaluate the engineering characteristics of the underlying materials. We conducted a detailed
engineering analysis of the site including settlement analysis and an assessment of the primary and secondary effects from seismic activity, including the potential for liquefaction and lateral spreading. Recommendations were provided for
foundation support through the loose sandy soils with a deep foundation system, mitigation of the potential effects of liquefaction/seismically induced settlements, and
overexcavation and recompaction of the surface soils for roadway and flatwork support.

Youngdahl continued services during grading operations in 2015. During the continued grading efforts, we have provided full time field inspection services with HAZWOPPER trained personnel to observed and document the compactive efforts.

We also aided in the locating of geotechnically suitable and unsuitable soils and with the environmental group in visual classification of soil for the various hazardous waste accepting facilities.

SMUD Station E
Sacramento, California
Client: Sacramento Municipal Utility
District (SMUD)
Contact: Ms. Joyce Hribar
(916) 732-5301
Project Cost: $89 Million
Key Elements
▪ Detailed Geotechnical Studies
▪ 40-hour OSHA Personnel
▪ Alternative foundation designs
including shallow footing, deep
piles and mat foundations
▪ Detailed Settlement Assessment
▪ Site Specific Site Response
▪ Liquefaction Analysis
▪ Groundwater Elevation
Assessment

AAAAAAAAAAAAAA
Youngdahl Consulting Group, Inc. began working on the site development for the new El Dorado County Public Safety
Facility in 2007. The site was formerly used for lumber storage and unauthorized dumping. Youngdahl worked with
prospective clients interested in the property to complete a Phase 1 Environmental Site Assessment (ESA) and
Geotechnical Engineering Study (GES). Our firm evaluated these previous conditions with respect to the proposed site use and provided recommendations for remediation
measures leading to a suitable site for construction.

In 2014, El Dorado County considered and ultimately selected the site for construction of the El Dorado County Public Safety Facility to centralize operations that currently were spread across 13 different locations in El Dorado County.

Construction operations for earthwork began in 2018; grading operations exposed large quantities of buried organic
material that were generated during past site uses. Our firm worked with the County and the design build Contractor to place these materials on-site in a fashion that would mitigate both environmental and geotechnical concerns. Additional challenges included variable foundation support conditions (rock surface and rock quality). Our team assured that the required support conditions were achieved to support the planned structures.

Youngdahl continued to provide special inspection and
materials testing services throughout site construction. When highly specialized fire damping evaluations were requested, Youngdahl subcontracted with a specialized firm from our experience on other pro jects, to quickly provide the County with the necessary resources. Youngdahl provided high - quality services while managing costs for this publicly funded project. We have continued to provide consulting services for stormwater compliance for the project.

El Dorado County Public
Safety Facility
Placerville, California
Owner:

County of El Dorado Facilities Division
Point Of Contact:

Mr. Bob Christenson
[email protected]
(530) 621-5104
Project Cost: $68 Million
Cost of Services: $290,000.00
Key Elements
▪ Detailed Geotechnical Studies
▪ Geophysical Investigations
▪ Earthwork Observation and
Testing
▪ All Special Inspection
o Structural Concrete
o Shotcrete
o Pre-Cast Concrete
o Post-tensioned Concrete
o Masonry
o Structural Steel Welding
o Fireproofing
o Non-Destructive Testing
▪ Laboratory Materials Testing

SECTION B

EXPERIENCE & REFERENCES

B.1-10

PROJECT EXPERIENCE

Power Plant/Energy Facility Licensing
Managed the preparation of air quality licensing
applications for over 2,000 megawatts of generating
capacity in California. Generating technologies have
included boilers, gas turbines, and reciprocating engines.

Fuels include natural gas, distillate fuel, biomass, digester gas, and landfill gas.

BAAQMD Permitting and Emission Inventory Support
Prepared BAAQMD Rule 12 -15 Refinery Emission Inventories for a hydrogen plant support facility.

Prepared permit applications and provided compliance support for BAAQMD facilities in the wastewater treatment, asphaltic concrete, aggregate, cement, cogeneration, and steel recycling industries.

NANSR and PSD Air Permitting
Managed the preparation of air permit applications for a wide range of sources subject to nonattainment new
source review and Prevention of Significant
Deterioration requirements. Application contents have
included applicability determinations, BACT/LAER
analyses, air quality impact analyses, and health risk
assessments. Support typically continues beyond permit
issuance through construction, commissioning, and
initial operation.

GHG Reporting, Verification, Rulemaking, and Compliance Support Prepared and submitted GHG emission reports under the U.S. Environmental Protection Agency and California Air Resources Board (CARB) Mandatory Reporting Rules for a variety of stationary sources, including and transportation fuels suppliers.

PROJECT EXPERIENCE

Assisted facilities in completing California GHG verification process. Negotiated various industry benchmark GHG emission values for the California Cap and Trade regulation. Provided compliance support for CARB enforcement actions.

AB 2588 Health Risk Assessment
Prepared facility-wide health risk assessments for various industrial sites and completed associated toxic emission inventory plans and reports in accordance with the regulations and guidance documents adopted pursuant to the California Air Toxics “Hot Spots” Information and Assessment Act of 1987 (AB 2588).

CEMS, Source Testing, and Ambient Monitoring
Designed and managed field programs for source (stack) testing for a variety of regulatory purposes.

Reviewed design, assisted in the procurement and installation of, and assisted with initial certification testing for CEMS and supporting data acquisition systems.

Regulatory Applicability and Compliance Support
Supported a broad range of clients in assessing compliance (through audits and other means) and defending enforcement actions and litigation threats. Support has included regulatory compliance audits; review of audit reports prepared by others; due diligen ce assessments prior to acquisitions; preparation of responses to EPA §114 requests; and representation in compliance negotiations and in formal variance/enforcement hearings.

Acid Rain Applicability and Permitting Support
Prepared Title IV Acid Rain permit applications and monitoring plans for power plants and provided ongoing technical support for Electronic Data Reporting. Prepared and submitted applicability analyses to EPA.

SECTION B

EXPERIENCE & REFERENCES

B.1-11

ŽŵƉĂƐƐ>ĂƌŐĞ,W;ϯϬϬ,WĂŶĚĂďŽǀĞͿZĞĨĞƌĞŶĐĞ>ŝƐƚ
AccountName:AccountName LocationCountry/International Market HP Driver Manufacturer Driver Model CompressorManufacturer Compressor Model OrderDate PecanPipelineCompany USA Rental 810 Caterpillar G3512LE GE 12/10/2016 EnergyTransferCanada(NOWPembina) Canada SaleCompression 1680 Waukesha L7044GSI Frick SGCBͲ3519 24/11/2016 EnergyTransferCanada(NOWPembina) Canada SaleCompression 1680 Waukesha L7044GSI Frick SGCBͲ3519 25/01/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 04/11/2016 E.S.FoxLtd. Canada SaleCompression 440 Electric Frick SGCͲ2313 15/11/2016 MeritageMidstreamServices Canada SaleProcess 400 Electric Ariel JGJ/2 09/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBU/4 10/01/2017 StormResourcesLtd. Canada SaleCompression 3550 Caterpillar G3612LE Ariel KBU/4 22/06/2017 CSVMidstreamSolutions Canada SaleCompression 400 Electric Ariel 07/03/2017 CSVMidstreamSolutions Canada SaleCompression 400 Electric RoFlo 07/03/2017 AthabascaOilCorporation Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/6 16/03/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 600 Electric RoFlo 03/05/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 EnergyTransferCanada(NOWPembina) Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 27/04/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 1300 Electric Ariel JGE/4 05/05/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 1300 Electric Ariel JGE/4 05/05/2017 EnergyTransferCanada(NOWPembina) Canada SaleCompression 2000 Electric Ariel JGK/6 26/05/2017 EnergyTransferCanada(NOWPembina) Canada Retrofit 2000 04/09/2019 EnergyTransferCanada(NOWPembina) Canada SaleCompression 2000 Electric Ariel JGK/6 26/05/2017 EnergyTransferCanada(NOWPembina) Canada Retrofit 2000 04/09/2019 PengrowthEnergy
Corporation Canada SaleCompression 1680 Waukesha L7044GSI Ariel JGK/4 07/06/2017 TesoroLogistics(NOWAndeavor) USA SaleCompression 3000 Electric Frick 11/07/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 300 Electric Ariel JG/4 06/07/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 350 Electric RoFlo 17S 02/08/2017 VelvetEnergyLtd.(NOWSpartanDeltaCorp) Canada Retrofit 1680 Waukesha L7044GSI Ariel JGK/4 23/08/2017 OrlenUpstreamCanadaLtd. Canada SaleCompression 2250 Waukesha P9390GSI Ariel JGD/4 08/09/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 1550 Electric Ariel JGD/4 21/08/2017 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 2370 Caterpillar GE 23/04/2018 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 2370 Caterpillar GE 23/04/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GL Frick NGC400F 20/12/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 26/10/2017 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 20/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 XTOEnergyInc. USA Rental 1680 Waukesha L7044GSI Ariel JGK/4 30/04/2018 ShellCanada Canada SaleCompression 325 Caterpillar G3406TA Ariel JGR/2 16/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 28/02/2018 PembinaPipelineCorporation Canada SaleCompression 850 Electric Ariel JGT/2 12/03/2018 PembinaPipelineCorporation Canada Retrofit 900 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 850 Electric Ariel JGT/2 12/03/2018 PembinaPipelineCorporation Canada Retrofit 900 11/12/2018 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 1150 Caterpillar G3516LE Ariel JGT/2 19/03/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 850 Electric Ariel JGJ/6 19/03/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 850 Electric Ariel JGJ/6 19/03/2018 Schlumberger USA SaleCompression 350 Electric Ariel 25/06/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 HaloExplorationLtd. Canada Rental 530 Waukesha H24GL Frick TDSHͲ283S 01/08/2018 BlackbirdEnergyInc.(NOWPipestoneEnergyCorp.) Canada SaleCompression 1900 Waukesha L7044GSI Ariel 14/08/2018 BlackbirdEnergyInc.(NOWPipestoneEnergyCorp.) Canada SaleCompression 1900 Waukesha L7044GSI Ariel 14/08/2018 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 1600 07/08/2018 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 300 Electric Ariel JG/4 25/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 TAQANorthLtd. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 22/06/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 350 Electric Ariel JGJ/2 06/06/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 350 Electric Ariel JGJ/2 06/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3306TA Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 Bapetco Egypt SaleCompression 2250 Waukesha P9390GSI Ariel JGK/4 27/06/2018 Bapetco Egypt SaleCompression 2250 Waukesha P9390GSI Ariel JGK/4 27/06/2018 StormResourcesLtd. Canada SaleCompression 1280 Waukesha L5774LT Frick SGCBͲ3515 25/09/2018 ParamountResourcesLtd. Canada SaleCompression 600 Electric Ariel JGH/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 600 Electric Ariel JGH/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 400 Electric Ariel JGJ/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 400 Electric Ariel JGJ/4 28/09/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 30/10/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 30/10/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GL Frick NGC400F 30/10/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 HaloExplorationLtd. Canada Rental 400 Waukesha F18GL Frick TDSHͲ283L 06/11/2018 ParamountResourcesLtd. Canada SaleCompression 450 Electric RoFlo 28/11/2018 EnhanceEnergyInc. Canada SaleCompression 1400 Electric Ariel 05/12/2018 SevenGenerationsEnergyLtd. Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 21/12/2018 GeneralEnergyRecovery Canada SaleCompression 400 Electric Ariel JGR/4 15/04/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 05/02/2019 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar Ariel 06/03/2019 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar Ariel 06/03/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 740 Waukesha F3514GSI Ariel JGK/2 14/03/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 740 Waukesha F3514GSI Ariel 14/03/2019 HilcorpAlaskaLLC USA SaleProcess 1950 Electric Frick 21/06/2019 AspenleafEnergyLtd.(ALE) Canada Retrofit 350 17/04/2019 PetronasCanada Canada SaleCompression 900 Electric Ariel JGK/2 30/04/2019 CaliberMidstream USA Rental 1150 Caterpillar Frick 23/08/2019 NuVistaEnergyLtd. Canada SaleCompression 300 Electric Ariel JGJ/2 16/05/2019 NuVistaEnergyLtd. Canada SaleCompression 300 Electric Ariel JGJ/2 16/05/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 2250 Waukesha Ariel JGD/4 08/05/2019 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/4 23/05/2019 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/6 23/05/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 MitsuiE&PAustraliaPtyLtd.(MEPAU) Australia SaleCompression 1004 Caterpillar G3512LE Ariel JGT/2 04/07/2019 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOil Corp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 26/05/2021 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 29/10/2019 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 CanadianNaturalResourcesLimited Canada SaleCompression 400 Electric RoFlo 05/11/2019 ImperialOilResourcesLimited Canada SaleCompression 350 Electric Ariel 06/12/2019 HuskyEnergyInc(NowCenovus) Canada SaleCompression 900 Electric Ariel 12/12/2019 OutriggerEnergyLLC USA SaleCompression 1800 Electric Ariel 23/12/2019 OutriggerEnergyLLC USA SaleCompression 1800 Electric Ariel 23/12/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 ConocoPhillipsCanada Canada SaleCompression 800 Electric Ariel JGT/4 28/09/2021 ConocoPhillipsCanada Canada SaleCompression 800 Electric Ariel JGT/4 28/09/2021 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 17/03/2020 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 17/03/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 ZetonInc. USA SaleCompression 300 Electric Ariel JGJ/4 27/09/2021 StormResourcesLtd. Canada SaleCompression 1875 Caterpillar G3606LE Ariel 05/11/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 PetronasCanada Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/04/2021 TAQANorthLtd. Canada SaleCompression 750 Electric Ariel JGJ/4 18/05/2021 AdvantageEnergyLtd. Canada SaleCompression 1300 Electric Ariel 19/05/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC450C 14/07/2021 StrathconaResourcesLtd. Canada Flip 1150 Caterpillar GE 22/07/2021 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/4 25/08/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha Frick 19/10/2021 StrathconaResourcesLtd. Canada SaleCompression 2500 Waukesha P9394GSI 23/09/2021 ATCOEnergySolutionsLtd. Canada SaleCompression 1900 Waukesha Ariel 28/09/2021 ATCOEnergySolutionsLtd. Canada SaleCompression 1900 Waukesha Ariel 28/09/2021 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 18/11/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 22/10/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9390GL 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystems Inc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 NAHelium Canada SaleCompression 350 Electric Ariel JGR/4 17/02/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 28/02/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 28/02/2022 AdvantageEnergyLtd. Canada SaleCompression 5000 Caterpillar G3616LE Ariel KBZ/6 06/04/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 30/03/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 30/03/2022 LeucrottaExploration(NOWCoelacanth) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 28/03/2022 LeucrottaExploration(NOWCoelacanth) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 28/03/2022 AltaGasLtd. Canada SaleCompression 1200 Electric Ariel 29/04/2022 AltaGasLtd. Canada SaleCompression 1200 Electric Ariel 29/04/2022 NAHelium Canada SaleCompression 900 Electric Mycom 21/04/2022 NAHelium Canada SaleCompression 900 Electric Mycom 21/04/2022 WestbrickEnergyLtd. Canada Flip 1680 Waukesha L7044GSI Ariel JGK/4 21/04/2022 WestbrickEnergyLtd. Canada Flip 1680 Waukesha L7044GSI Ariel JGK/4 21/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA Sale Compression 2500 Waukesha P9394GSI 27/04/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 19/05/2022 CenovusEnergyInc. Canada SaleCompression 1900 Waukesha Ariel 19/05/2022 NAHelium Canada SaleCompression 350 Electric Ariel 27/05/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 PacificCanbriamEnergyInc. Canada SaleCompression 2500 Caterpillar Frick 14/06/2022 TundraOil&Gas Canada Flip 350 Electric Ariel 27/06/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 ZetonInc. USA SaleCompression 300 Electric Ariel JGJ/4 27/09/2021 StormResourcesLtd. Canada SaleCompression 1875 Caterpillar G3606LE Ariel 05/11/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 PetronasCanada Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/04/2021 TAQANorthLtd. Canada SaleCompression 750 Electric Ariel JGJ/4 18/05/2021 AdvantageEnergyLtd. Canada SaleCompression 1300 Electric Ariel 19/05/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC450C 14/07/2021 StrathconaResourcesLtd. Canada Flip 1150 Caterpillar GE 22/07/2021 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/4 25/08/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha Frick 19/10/2021 StrathconaResourcesLtd. Canada SaleCompression 2500 Waukesha P9394GSI 23/09/2021 ATCOEnergySolutionsLtd. Canada SaleCompression 1900 Waukesha Ariel 28/09/2021 ATCOEnergySolutionsLtd. Canada SaleCompression 1900 Waukesha Ariel 28/09/2021 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 18/11/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 22/10/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9390GL 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystems Inc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 NAHelium Canada SaleCompression 350 Electric Ariel JGR/4 17/02/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 28/02/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 28/02/2022 AdvantageEnergyLtd. Canada SaleCompression 5000 Caterpillar G3616LE Ariel KBZ/6 06/04/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 30/03/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 30/03/2022 LeucrottaExploration(NOWCoelacanth) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 28/03/2022 LeucrottaExploration(NOWCoelacanth) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 28/03/2022 AltaGasLtd. Canada SaleCompression 1200 Electric Ariel 29/04/2022 AltaGasLtd. Canada SaleCompression 1200 Electric Ariel 29/04/2022 NAHelium Canada SaleCompression 900 Electric Mycom 21/04/2022 NAHelium Canada SaleCompression 900 Electric Mycom 21/04/2022 WestbrickEnergyLtd. Canada Flip 1680 Waukesha L7044GSI Ariel JGK/4 21/04/2022 WestbrickEnergyLtd. Canada Flip 1680 Waukesha L7044GSI Ariel JGK/4 21/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 19/05/2022 CenovusEnergy
Inc. Canada SaleCompression 1900 Waukesha Ariel 19/05/2022 NAHelium Canada SaleCompression 350 Electric Ariel 27/05/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 PacificCanbriamEnergyInc. Canada SaleCompression 2500 Caterpillar Frick 14/06/2022 TundraOil&Gas Canada Flip 350 Electric Ariel 27/06/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CenovusEnergyInc. Canada SaleCompression 1900 Waukesha L7044GSI Ariel 12/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 HammerheadResourcesInc. Canada SaleCompression 300 Electric Ariel JGR/2 20/10/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 1875 Caterpillar G3606LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha Ariel JGJ/2 12/01/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha Ariel JGJ/2 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 NAHelium Canada SaleCompression 400 Electric Ariel JGJ/2 05/01/2023 NAHelium Canada SaleCompression 400 Electric Ariel JGJ/2 05/01/2023 PetronasCanada Canada SaleCompression 2500 Caterpillar Ariel 18/01/2023 ParamountResourcesLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 11/01/2023 ParamountResourcesLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 11/01/2023 NAHelium Canada SaleCompression 300 Electric Frick 17/02/2023 NAHelium Canada SaleCompression 300 Electric Frick 17/02/2023 CoelacanthEnergy
Inc. Canada SaleCompression 3850 Caterpillar Ariel KBZ/4 01/06/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSI Ariel JGD/4 31/03/2023 StrathconaResourcesLtd. Canada SaleCompression 3750 Caterpillar Ariel 29/03/2023 InsigniaEnergyLtd. Canada SaleCompression 1900 Waukesha Ariel 25/05/2023 NAHelium Canada SaleCompression 1500 Electric Ariel 29/05/2023 NAHelium Canada SaleCompression 1500 Electric Ariel 29/05/2023 OXY USA SaleCompression 1600 Electric Ariel 14/07/2023 OXY USA SaleCompression 1600 Electric Ariel 14/07/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 31/07/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 31/07/2023 CanadianNaturalResourcesLimited Canada SaleCompression 1250 Electric Frick SGCͲ2821 09/02/2024 NorthRiverMidstream Canada SaleCompression 2250 30/11/2023 NorthRiverMidstream Canada SaleCompression 2500 Electric Ariel 30/11/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 ParamountResourcesLtd. Canada SaleCompression 1200 Electric Ariel JGJ/4 21/11/2023 ParamountResourcesLtd. Canada SaleCompression 2500 Electric Ariel JGD/4 21/11/2023 ParamountResourcesLtd. Canada SaleCompression 2500 Electric Ariel JGD/4 21/11/2023 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 08/01/2024 TidewaterMidstreamandInfrastructure Ltd. Canada SaleCompression 6500 Electric Ariel KBZ/6 08/01/2024 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 08/01/2024 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 08/01/2024 NorthRiverMidstream Canada SaleCompression 300 Electric Ariel 30/01/2024 AltaGasLtd. Canada SaleCompression 1900 Electric Ariel 31/03/2024 AltaGasLtd. Canada SaleCompression 1900 Electric Ariel 31/03/2024 ZargonOil&GasLtd. 0 SaleCompression 420 Cummins GD 03/04/2007 CrewEnergyInc. Canada Rental 420 Cummins KTA19 GD 08/05/2014 SIWAPETROLEUMDMCC Pakistan SaleCompression 450 08/12/2008 SummitMidstreamPartners,LLC USA RentalSale 738 Waukesha F3514GSI Ariel JGH/4 27/06/2014 PetrogasEnergyCorp.(NOWAltaGasLtd.) 0 SaleCompression 1478 12/02/2010 ConocoPhillipsCanada 0 SaleCompression 1478 02/02/2010 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 24/03/2010 ADDEMIREL Turkey SaleCompression 400 Caterpillar G3408TA Sullair PC25S 24/03/2010 FerusInc. USA Rental 400 Waukesha F18GSI Ariel JGJ/4 09/09/2014 CrescentPointEnergyCorp. Canada Rental 400 Waukesha F18GL Ariel JGJ/4 01/02/2017 BullMooseCapitalLtd. Canada Flip 400 Waukesha Ariel 14/12/2021 ArtisExplorationLtd. Canada Rental 400 Waukesha F18GL Ariel JGJ/2 31/05/2018 HaloExplorationLtd. Canada Flip 400 Waukesha Ariel 01/04/2022 AnadarkoPetroleumCorporation USA SaleCompression 1380 04/08/2010 AnadarkoPetroleumCorporation USA SaleCompression 690 04/08/2010 S&WEnergySolutionsInc. Venezuela SaleCompression 600 Electric Ariel JGJ/2 04/02/2010 S&WEnergySolutionsInc. Venezuela SaleCompression 600 Electric Ariel JGJ/2 17/02/2010 HuskyEnergyInc(NowCenovus) 0 SaleCompression 740 21/07/2010 HuskyEnergyInc(NowCenovus) Canada SaleCompression 574 21/12/2010 LakustaEnergyServices(1994)Ltd. Canada SaleCompression 1250 08/11/2010 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 03/02/2011 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 03/02/2011 HuskyEnergyInc(NowCenovus) Canada SaleCompression 300 27/01/2011 PetronasDaganganBerhad Malaysia SaleCompression 4735 Caterpillar G3616LE Ariel KBZ/6 29/11/2011 ParamountResourcesLtd. Canada SaleCompression 3550 Caterpillar G3612LE 17/02/2011 ENXCompressors,S.A.deC.V. Mexico SaleCompression 1480 07/04/2011 BlaiseEnergyInc. USA Rental 400 Ariel JGA/4 05/02/2019 EOGResources,Inc. USA Retrofit 670 Caterpillar Ariel 29/07/2015 PegsaLtda. Colombia SaleCompression 530 Waukesha H24GL Ariel JGJ/2 12/08/2015 FerusInc. Canada SaleCompression 325 Caterpillar G3406TA Ariel JGA/4 29/09/2015 SevenGenerationsEnergyLtd. Canada Rental 1450 09/07/2019 SpectraEnergyCanadaGasTransmissionInc.(NOWEnbridgeInc.) Canada SaleCompression 3750 Caterpillar G3512LE Ariel JGC/4 14/10/2015 EOGResources,Inc. USA Retrofit 670 Caterpillar Ariel 10/11/2015 EOGResources,Inc. USA Retrofit 670 Caterpillar G3508LE Ariel JGJ/4 10/11/2015 ARCResourcesLtd. Canada SaleCompression 600 Electric Ariel JGJ/2 16/12/2015 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 400 Electric Ariel JGR/4 22/12/2015 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 300 Electric RoFlo 19S 22/12/2015 UnconventionalGasResourcesCanadaOperatingInc.(NOWPaintedPony) Canada Rental 530 Waukesha H24GL Ariel JGJ/2 07/01/2016 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 23/02/2016 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 1250 Waukesha L5774LT Frick SGCͲ2821 23/02/2016 WBIEnergyMidstream USA SaleCompression 1775 Caterpillar G3606LE Ariel JGK/4 07/06/2016 WBIEnergyMidstream USA SaleCompression 750 Electric Ariel JGT/2 07/06/2016 WBIEnergyMidstream USA SaleCompression 1380 Caterpillar G3516BLE Ariel JGT/4 07/06/2016 BlackbirdEnergyInc.(NOWPipestoneEnergyCorp.) Canada SaleCompression 300 Electric Ariel JG/4 07/06/2016 PetrogasEnergyCorp.(NOWAltaGasLtd.) Canada SaleCompression 600 Caterpillar Frick SGCBͲ3519 11/07/2016 PetrogasEnergyCorp.(NOWAltaGasLtd.) Canada SaleCompression 600 Caterpillar Frick SGCBͲ3519 11/07/2016 AthabascaOilCorporation Canada SaleCompression 2445 Caterpillar G3608LE Ariel JGC/4 17/08/2016 AthabascaOilCorporation Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/6 17/08/2016 PennWestPetroleumLtd.(NOWObsidianEnergyLtd.) Canada SaleCompression 325 Caterpillar G3406TA Frick TDSHͲ233XL 09/12/2016 PennWestPetroleumLtd.(NOWObsidianEnergyLtd.) Canada SaleCompression 325 Caterpillar G3406TA RoFlo 4CC 09/12/2016 OvintivCanadaULC(EncanaCorporation) Canada Rental 530 Waukesha H24GL Ariel JGJ/2 07/02/2018 NuVistaEnergyLtd. Canada Rental 530 09/07/2019
PembinaPipelineCorporation Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 07/09/2016 Pembina
PipelineCorporation Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 07/09/2016 CanadianNaturalResourcesLimited Canada MajorProject 400 Electric RoFlo 05/11/2019 VoltaGrid USA SaleCompression 700 Electric Ariel JGA/6 07/07/2022 VoltaGrid USA SaleCompression 700 Electric Ariel JGA/6 07/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGC/4 24/02/2023 BlaiseEnergyInc. USA Rental 400 Ariel JGA/4 05/02/2019 EOGResources,Inc. USA Retrofit 670 Caterpillar Ariel 29/07/2015 PegsaLtda. Colombia SaleCompression 530 Waukesha H24GL Ariel JGJ/2 12/08/2015 FerusInc. Canada SaleCompression 325 Caterpillar G3406TA Ariel JGA/4 29/09/2015 SevenGenerationsEnergyLtd. Canada Rental 1450 09/07/2019 SpectraEnergyCanadaGasTransmissionInc.(NOWEnbridgeInc.) Canada SaleCompression 3750 Caterpillar G3512LE Ariel JGC/4 14/10/2015 EOGResources,Inc. USA Retrofit 670 Caterpillar Ariel 10/11/2015 EOGResources,Inc. USA Retrofit 670 Caterpillar G3508LE Ariel JGJ/4 10/11/2015 ARCResourcesLtd. Canada SaleCompression 600 Electric Ariel JGJ/2 16/12/2015 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 400 Electric Ariel JGR/4 22/12/2015 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 300 Electric RoFlo 19S 22/12/2015 UnconventionalGasResourcesCanadaOperatingInc.(NOWPaintedPony) Canada Rental 530 Waukesha H24GL Ariel JGJ/2 07/01/2016 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 23/02/2016 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 1250 Waukesha L5774LT Frick SGCͲ2821 23/02/2016 WBIEnergyMidstream USA SaleCompression 1775 Caterpillar G3606LE Ariel JGK/4 07/06/2016 WBIEnergyMidstream USA SaleCompression 750 Electric Ariel JGT/2 07/06/2016 WBIEnergyMidstream USA SaleCompression 1380 Caterpillar G3516BLE Ariel JGT/4 07/06/2016 BlackbirdEnergyInc.(NOWPipestoneEnergyCorp.) Canada SaleCompression 300 Electric Ariel JG/4 07/06/2016 PetrogasEnergyCorp.(NOWAltaGasLtd.) Canada SaleCompression 600 Caterpillar Frick SGCBͲ3519 11/07/2016 PetrogasEnergyCorp.(NOWAltaGasLtd.) Canada SaleCompression 600 Caterpillar Frick SGCBͲ3519 11/07/2016 AthabascaOilCorporation Canada SaleCompression 2445 Caterpillar G3608LE Ariel JGC/4 17/08/2016 AthabascaOilCorporation Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/6 17/08/2016 PennWestPetroleumLtd.(NOWObsidianEnergyLtd.) Canada SaleCompression 325 Caterpillar G3406TA Frick TDSHͲ233XL 09/12/2016 PennWestPetroleumLtd.(NOWObsidianEnergyLtd.) Canada SaleCompression 325 Caterpillar G3406TA RoFlo 4CC 09/12/2016 OvintivCanadaULC(EncanaCorporation) Canada Rental 530 Waukesha H24GL Ariel JGJ/2 07/02/2018 NuVistaEnergyLtd. Canada Rental 530 09/07/2019
PembinaPipelineCorporation Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 07/09/2016 Pembina
PipelineCorporation Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 07/09/2016 CanadianNaturalResourcesLimited Canada MajorProject 400 Electric RoFlo 05/11/2019 VoltaGrid USA SaleCompression 700 Electric Ariel JGA/6 07/07/2022 VoltaGrid USA SaleCompression 700 Electric Ariel JGA/6 07/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGC/4 24/02/2023 ŽŵƉĂƐƐ>ĂƌŐĞ,W;ϯϬϬ,WĂŶĚĂďŽǀĞͿZĞĨĞƌĞŶĐĞ>ŝƐƚ
AccountName:AccountName LocationCountry/International Market HP Driver Manufacturer Driver Model CompressorManufacturer Compressor Model OrderDate PecanPipelineCompany USA Rental 810 Caterpillar G3512LE GE 12/10/2016 EnergyTransferCanada(NOWPembina) Canada SaleCompression 1680 Waukesha L7044GSI Frick SGCBͲ3519 24/11/2016 EnergyTransferCanada(NOWPembina) Canada SaleCompression 1680 Waukesha L7044GSI Frick SGCBͲ3519 25/01/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 04/11/2016 E.S.FoxLtd. Canada SaleCompression 440 Electric Frick SGCͲ2313 15/11/2016 MeritageMidstreamServices Canada SaleProcess 400 Electric Ariel JGJ/2 09/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBU/4 10/01/2017 StormResourcesLtd. Canada SaleCompression 3550 Caterpillar G3612LE Ariel KBU/4 22/06/2017 CSVMidstreamSolutions Canada SaleCompression 400 Electric Ariel 07/03/2017 CSVMidstreamSolutions Canada SaleCompression 400 Electric RoFlo 07/03/2017 AthabascaOilCorporation Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/6 16/03/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 600 Electric RoFlo 03/05/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 EnergyTransferCanada(NOWPembina) Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 27/04/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 1300 Electric Ariel JGE/4 05/05/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 1300 Electric Ariel JGE/4 05/05/2017 EnergyTransferCanada(NOWPembina) Canada SaleCompression 2000 Electric Ariel JGK/6 26/05/2017 EnergyTransferCanada(NOWPembina) Canada Retrofit 2000 04/09/2019 EnergyTransferCanada(NOWPembina) Canada SaleCompression 2000 Electric Ariel JGK/6 26/05/2017 EnergyTransferCanada(NOWPembina) Canada Retrofit 2000 04/09/2019 PengrowthEnergy
Corporation Canada SaleCompression 1680 Waukesha L7044GSI Ariel JGK/4 07/06/2017 TesoroLogistics(NOWAndeavor) USA SaleCompression 3000 Electric Frick 11/07/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 300 Electric Ariel JG/4 06/07/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 350 Electric RoFlo 17S 02/08/2017 VelvetEnergyLtd.(NOWSpartanDeltaCorp) Canada Retrofit 1680 Waukesha L7044GSI Ariel JGK/4 23/08/2017 OrlenUpstreamCanadaLtd. Canada SaleCompression 2250 Waukesha P9390GSI Ariel JGD/4 08/09/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 1550 Electric Ariel JGD/4 21/08/2017 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 2370 Caterpillar GE 23/04/2018 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 2370 Caterpillar GE 23/04/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GL Frick NGC400F 20/12/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 26/10/2017 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 20/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 XTOEnergyInc. USA Rental 1680 Waukesha L7044GSI Ariel JGK/4 30/04/2018 ShellCanada Canada SaleCompression 325 Caterpillar G3406TA Ariel JGR/2 16/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 28/02/2018 PembinaPipelineCorporation Canada SaleCompression 850 Electric Ariel JGT/2 12/03/2018 PembinaPipelineCorporation Canada Retrofit 900 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 850 Electric Ariel JGT/2 12/03/2018 PembinaPipelineCorporation Canada Retrofit 900 11/12/2018 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 1150 Caterpillar G3516LE Ariel JGT/2 19/03/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 850 Electric Ariel JGJ/6 19/03/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 850 Electric Ariel JGJ/6 19/03/2018 Schlumberger USA SaleCompression 350 Electric Ariel 25/06/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 Regent
PowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 HaloExplorationLtd. Canada Rental 530 Waukesha H24GL Frick TDSHͲ283S 01/08/2018 BlackbirdEnergyInc.(NOWPipestoneEnergyCorp.) Canada SaleCompression 1900 Waukesha L7044GSI Ariel 14/08/2018 BlackbirdEnergyInc.(NOWPipestoneEnergyCorp.) Canada SaleCompression 1900 Waukesha L7044GSI Ariel 14/08/2018 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 1600 07/08/2018 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 300 Electric Ariel JG/4 25/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 TAQANorthLtd. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 22/06/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 350 Electric Ariel JGJ/2 06/06/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 350 Electric Ariel JGJ/2 06/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3306TA Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 Bapetco Egypt SaleCompression 2250 Waukesha P9390GSI Ariel JGK/4 27/06/2018 Bapetco Egypt SaleCompression 2250 Waukesha P9390GSI Ariel JGK/4 27/06/2018 StormResourcesLtd. Canada SaleCompression 1280 Waukesha L5774LT Frick SGCBͲ3515 25/09/2018 ParamountResourcesLtd. Canada SaleCompression 600 Electric Ariel JGH/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 600 Electric Ariel JGH/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 400 Electric Ariel JGJ/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 400 Electric Ariel JGJ/4 28/09/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 30/10/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 30/10/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GL Frick NGC400F 30/10/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 HaloExplorationLtd. Canada Rental 400 Waukesha F18GL Frick TDSHͲ283L 06/11/2018 ParamountResourcesLtd. Canada SaleCompression 450 Electric RoFlo 28/11/2018 EnhanceEnergyInc. Canada SaleCompression 1400 Electric Ariel 05/12/2018 SevenGenerationsEnergyLtd. Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 21/12/2018 GeneralEnergyRecovery Canada SaleCompression 400 Electric Ariel JGR/4 15/04/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 05/02/2019 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar Ariel 06/03/2019 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar Ariel 06/03/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 740 Waukesha F3514GSI Ariel JGK/2 14/03/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 740 Waukesha F3514GSI Ariel 14/03/2019 HilcorpAlaskaLLC USA SaleProcess 1950 Electric Frick 21/06/2019 AspenleafEnergyLtd.(ALE) Canada Retrofit 350 17/04/2019 PetronasCanada Canada SaleCompression 900 Electric Ariel JGK/2 30/04/2019 CaliberMidstream USA Rental 1150 Caterpillar Frick 23/08/2019 NuVistaEnergyLtd. Canada SaleCompression 300 Electric Ariel JGJ/2 16/05/2019 NuVistaEnergyLtd. Canada SaleCompression 300 Electric Ariel JGJ/2 16/05/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 2250 Waukesha Ariel JGD/4 08/05/2019 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/4 23/05/2019 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/6 23/05/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 MitsuiE&PAustraliaPtyLtd.(MEPAU) Australia SaleCompression 1004 Caterpillar G3512LE Ariel JGT/2 04/07/2019 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOil Corp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 26/05/2021 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 29/10/2019 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 CanadianNaturalResourcesLimited Canada SaleCompression 400 Electric RoFlo 05/11/2019 ImperialOilResourcesLimited Canada SaleCompression 350 Electric Ariel 06/12/2019 HuskyEnergyInc(NowCenovus) Canada SaleCompression 900 Electric Ariel 12/12/2019 OutriggerEnergyLLC USA SaleCompression 1800 Electric Ariel 23/12/2019 OutriggerEnergyLLC USA SaleCompression 1800 Electric Ariel 23/12/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 ConocoPhillipsCanada Canada SaleCompression 800 Electric Ariel JGT/4 28/09/2021 ConocoPhillipsCanada Canada SaleCompression 800 Electric Ariel JGT/4 28/09/2021 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 17/03/2020 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 17/03/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 ZetonInc. USA SaleCompression 300 Electric Ariel JGJ/4 27/09/2021 StormResourcesLtd. Canada SaleCompression 1875 Caterpillar G3606LE Ariel 05/11/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 PetronasCanada Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/04/2021 TAQANorthLtd. Canada SaleCompression 750 Electric Ariel JGJ/4 18/05/2021 AdvantageEnergyLtd. Canada SaleCompression 1300 Electric Ariel 19/05/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC450C 14/07/2021 StrathconaResourcesLtd. Canada Flip 1150 Caterpillar GE 22/07/2021 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/4 25/08/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha Frick 19/10/2021 StrathconaResourcesLtd. Canada SaleCompression 2500 Waukesha P9394GSI 23/09/2021 ATCOEnergySolutionsLtd. Canada SaleCompression 1900 Waukesha Ariel 28/09/2021 ATCOEnergySolutionsLtd. Canada SaleCompression 1900 Waukesha Ariel 28/09/2021 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 18/11/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 22/10/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9390GL 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystems Inc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 NAHelium Canada SaleCompression 350 Electric Ariel JGR/4 17/02/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 28/02/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 28/02/2022 AdvantageEnergyLtd. Canada SaleCompression 5000 Caterpillar G3616LE Ariel KBZ/6 06/04/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 30/03/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 30/03/2022 LeucrottaExploration(NOWCoelacanth) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 28/03/2022 LeucrottaExploration(NOWCoelacanth) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 28/03/2022 AltaGasLtd. Canada SaleCompression 1200 Electric Ariel 29/04/2022 AltaGasLtd. Canada SaleCompression 1200 Electric Ariel 29/04/2022 NAHelium Canada SaleCompression 900 Electric Mycom 21/04/2022 NAHelium Canada SaleCompression 900 Electric Mycom 21/04/2022 WestbrickEnergyLtd. Canada Flip 1680 Waukesha L7044GSI Ariel JGK/4 21/04/2022 WestbrickEnergyLtd. Canada Flip 1680 Waukesha L7044GSI Ariel JGK/4 21/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA Sale Compression 2500 Waukesha P9394GSI 27/04/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 19/05/2022 CenovusEnergyInc. Canada SaleCompression 1900 Waukesha Ariel 19/05/2022 NAHelium Canada SaleCompression 350 Electric Ariel 27/05/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 PacificCanbriamEnergyInc. Canada SaleCompression 2500 Caterpillar Frick 14/06/2022 TundraOil&Gas Canada Flip 350 Electric Ariel 27/06/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 ŽŵƉĂƐƐ>ĂƌŐĞ,W;ϯϬϬ,WĂŶĚĂďŽǀĞͿZĞĨĞƌĞŶĐĞ>ŝƐƚ
AccountName:AccountName LocationCountry/International Market HP Driver Manufacturer Driver Model CompressorManufacturer Compressor Model OrderDate PecanPipelineCompany USA Rental 810 Caterpillar G3512LE GE 12/10/2016 EnergyTransferCanada(NOWPembina) Canada SaleCompression 1680 Waukesha L7044GSI Frick SGCBͲ3519 24/11/2016 EnergyTransferCanada(NOWPembina) Canada SaleCompression 1680 Waukesha L7044GSI Frick SGCBͲ3519 25/01/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 04/11/2016 E.S.FoxLtd. Canada SaleCompression 440 Electric Frick SGCͲ2313 15/11/2016 MeritageMidstreamServices Canada SaleProcess 400 Electric Ariel JGJ/2 09/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBU/4 10/01/2017 StormResourcesLtd. Canada SaleCompression 3550 Caterpillar G3612LE Ariel KBU/4 22/06/2017 CSVMidstreamSolutions Canada SaleCompression 400 Electric Ariel 07/03/2017 CSVMidstreamSolutions Canada SaleCompression 400 Electric RoFlo 07/03/2017 AthabascaOilCorporation Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/6 16/03/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 600 Electric RoFlo 03/05/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 EnergyTransferCanada(NOWPembina) Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 27/04/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 1300 Electric Ariel JGE/4 05/05/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 1300 Electric Ariel JGE/4 05/05/2017 EnergyTransferCanada(NOWPembina) Canada SaleCompression 2000 Electric Ariel JGK/6 26/05/2017 EnergyTransferCanada(NOWPembina) Canada Retrofit 2000 04/09/2019 EnergyTransferCanada(NOWPembina) Canada SaleCompression 2000 Electric Ariel JGK/6 26/05/2017 EnergyTransferCanada(NOWPembina) Canada Retrofit 2000 04/09/2019 PengrowthEnergy
Corporation Canada SaleCompression 1680 Waukesha L7044GSI Ariel JGK/4 07/06/2017 TesoroLogistics(NOWAndeavor) USA SaleCompression 3000 Electric Frick 11/07/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 300 Electric Ariel JG/4 06/07/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 350 Electric RoFlo 17S 02/08/2017 VelvetEnergyLtd.(NOWSpartanDeltaCorp) Canada Retrofit 1680 Waukesha L7044GSI Ariel JGK/4 23/08/2017 OrlenUpstreamCanadaLtd. Canada SaleCompression 2250 Waukesha P9390GSI Ariel JGD/4 08/09/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 1550 Electric Ariel JGD/4 21/08/2017 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 2370 Caterpillar GE 23/04/2018 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 2370 Caterpillar GE 23/04/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GL Frick NGC400F 20/12/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 26/10/2017 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 20/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 XTOEnergyInc. USA Rental 1680 Waukesha L7044GSI Ariel JGK/4 30/04/2018 ShellCanada Canada SaleCompression 325 Caterpillar G3406TA Ariel JGR/2 16/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 28/02/2018 PembinaPipelineCorporation Canada SaleCompression 850 Electric Ariel JGT/2 12/03/2018 PembinaPipelineCorporation Canada Retrofit 900 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 850 Electric Ariel JGT/2 12/03/2018 PembinaPipelineCorporation Canada Retrofit 900 11/12/2018 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 1150 Caterpillar G3516LE Ariel JGT/2 19/03/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 850 Electric Ariel JGJ/6 19/03/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 850 Electric Ariel JGJ/6 19/03/2018 Schlumberger USA SaleCompression 350 Electric Ariel 25/06/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 HaloExplorationLtd. Canada Rental 530 Waukesha H24GL Frick TDSHͲ283S 01/08/2018 BlackbirdEnergyInc.(NOWPipestoneEnergyCorp.) Canada SaleCompression 1900 Waukesha L7044GSI Ariel 14/08/2018 BlackbirdEnergyInc.(NOWPipestoneEnergyCorp.) Canada SaleCompression 1900 Waukesha L7044GSI Ariel 14/08/2018 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 1600 07/08/2018 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 300 Electric Ariel JG/4 25/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 TAQANorthLtd. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 22/06/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 350 Electric Ariel JGJ/2 06/06/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 350 Electric Ariel JGJ/2 06/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3306TA Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 Bapetco Egypt SaleCompression 2250 Waukesha P9390GSI Ariel JGK/4 27/06/2018 Bapetco Egypt SaleCompression 2250 Waukesha P9390GSI Ariel JGK/4 27/06/2018 StormResourcesLtd. Canada SaleCompression 1280 Waukesha L5774LT Frick SGCBͲ3515 25/09/2018 ParamountResourcesLtd. Canada SaleCompression 600 Electric Ariel JGH/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 600 Electric Ariel JGH/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 400 Electric Ariel JGJ/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 400 Electric Ariel JGJ/4 28/09/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 30/10/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 30/10/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GL Frick NGC400F 30/10/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 HaloExplorationLtd. Canada Rental 400 Waukesha F18GL Frick TDSHͲ283L 06/11/2018 ParamountResourcesLtd. Canada SaleCompression 450 Electric RoFlo 28/11/2018 EnhanceEnergyInc. Canada SaleCompression 1400 Electric Ariel 05/12/2018 SevenGenerationsEnergyLtd. Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 21/12/2018 GeneralEnergyRecovery Canada SaleCompression 400 Electric Ariel JGR/4 15/04/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 05/02/2019 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar Ariel 06/03/2019 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar Ariel 06/03/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 740 Waukesha F3514GSI Ariel JGK/2 14/03/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 740 Waukesha F3514GSI Ariel 14/03/2019 HilcorpAlaskaLLC USA SaleProcess 1950 Electric Frick 21/06/2019 AspenleafEnergyLtd.(ALE) Canada Retrofit 350 17/04/2019 PetronasCanada Canada SaleCompression 900 Electric Ariel JGK/2 30/04/2019 CaliberMidstream USA Rental 1150 Caterpillar Frick 23/08/2019 NuVistaEnergyLtd. Canada SaleCompression 300 Electric Ariel JGJ/2 16/05/2019 NuVistaEnergyLtd. Canada SaleCompression 300 Electric Ariel JGJ/2 16/05/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 2250 Waukesha Ariel JGD/4 08/05/2019 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/4 23/05/2019 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/6 23/05/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 MitsuiE&PAustraliaPtyLtd.(MEPAU) Australia SaleCompression 1004 Caterpillar G3512LE Ariel JGT/2 04/07/2019 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOil Corp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 26/05/2021 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 29/10/2019 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 CanadianNaturalResourcesLimited Canada SaleCompression 400 Electric RoFlo 05/11/2019 ImperialOilResourcesLimited Canada SaleCompression 350 Electric Ariel 06/12/2019 HuskyEnergyInc(NowCenovus) Canada SaleCompression 900 Electric Ariel 12/12/2019 OutriggerEnergyLLC USA SaleCompression 1800 Electric Ariel 23/12/2019 OutriggerEnergyLLC USA SaleCompression 1800 Electric Ariel 23/12/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 ConocoPhillipsCanada Canada SaleCompression 800 Electric Ariel JGT/4 28/09/2021 ConocoPhillipsCanada Canada SaleCompression 800 Electric Ariel JGT/4 28/09/2021 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 17/03/2020 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 17/03/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 ZetonInc. USA SaleCompression 300 Electric Ariel JGJ/4 27/09/2021 StormResourcesLtd. Canada SaleCompression 1875 Caterpillar G3606LE Ariel 05/11/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 PetronasCanada Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/04/2021 TAQANorthLtd. Canada SaleCompression 750 Electric Ariel JGJ/4 18/05/2021 AdvantageEnergyLtd. Canada SaleCompression 1300 Electric Ariel 19/05/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC450C 14/07/2021 StrathconaResourcesLtd. Canada Flip 1150 Caterpillar GE 22/07/2021 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/4 25/08/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha Frick 19/10/2021 StrathconaResourcesLtd. Canada SaleCompression 2500 Waukesha P9394GSI 23/09/2021 ATCOEnergySolutionsLtd. Canada SaleCompression 1900 Waukesha Ariel 28/09/2021 ATCOEnergySolutionsLtd. Canada SaleCompression 1900 Waukesha Ariel 28/09/2021 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 18/11/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 22/10/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9390GL 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystems Inc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 NAHelium Canada SaleCompression 350 Electric Ariel JGR/4 17/02/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 28/02/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 28/02/2022 AdvantageEnergyLtd. Canada SaleCompression 5000 Caterpillar G3616LE Ariel KBZ/6 06/04/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 30/03/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 30/03/2022 LeucrottaExploration(NOWCoelacanth) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 28/03/2022 LeucrottaExploration(NOWCoelacanth) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 28/03/2022 AltaGasLtd. Canada SaleCompression 1200 Electric Ariel 29/04/2022 AltaGasLtd. Canada SaleCompression 1200 Electric Ariel 29/04/2022 NAHelium Canada SaleCompression 900 Electric Mycom 21/04/2022 NAHelium Canada SaleCompression 900 Electric Mycom 21/04/2022 WestbrickEnergyLtd. Canada Flip 1680 Waukesha L7044GSI Ariel JGK/4 21/04/2022 WestbrickEnergyLtd. Canada Flip 1680 Waukesha L7044GSI Ariel JGK/4 21/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA Sale Compression 2500 Waukesha P9394GSI 27/04/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 19/05/2022 CenovusEnergyInc. Canada SaleCompression 1900 Waukesha Ariel 19/05/2022 NAHelium Canada SaleCompression 350 Electric Ariel 27/05/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 PacificCanbriamEnergyInc. Canada SaleCompression 2500 Caterpillar Frick 14/06/2022 TundraOil&Gas Canada Flip 350 Electric Ariel 27/06/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022

ŽŵƉĂƐƐ>ĂƌŐĞ,W;ϯϬϬ,WĂŶĚĂďŽǀĞͿZĞĨĞƌĞŶĐĞ>ŝƐƚ
AccountName:AccountName LocationCountry/International Market HP Driver Manufacturer Driver Model CompressorManufacturer Compressor Model OrderDate PecanPipelineCompany USA Rental 810 Caterpillar G3512LE GE 12/10/2016 EnergyTransferCanada(NOWPembina) Canada SaleCompression 1680 Waukesha L7044GSI Frick SGCBͲ3519 24/11/2016 EnergyTransferCanada(NOWPembina) Canada SaleCompression 1680 Waukesha L7044GSI Frick SGCBͲ3519 25/01/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 04/11/2016 E.S.FoxLtd. Canada SaleCompression 440 Electric Frick SGCͲ2313 15/11/2016 MeritageMidstreamServices Canada SaleProcess 400 Electric Ariel JGJ/2 09/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBU/4 10/01/2017 StormResourcesLtd. Canada SaleCompression 3550 Caterpillar G3612LE Ariel KBU/4 22/06/2017 CSVMidstreamSolutions Canada SaleCompression 400 Electric Ariel 07/03/2017 CSVMidstreamSolutions Canada SaleCompression 400 Electric RoFlo 07/03/2017 AthabascaOilCorporation Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/6 16/03/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 600 Electric RoFlo 03/05/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 EnergyTransferCanada(NOWPembina) Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 27/04/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 1300 Electric Ariel JGE/4 05/05/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 1300 Electric Ariel JGE/4 05/05/2017 EnergyTransferCanada(NOWPembina) Canada SaleCompression 2000 Electric Ariel JGK/6 26/05/2017 EnergyTransferCanada(NOWPembina) Canada Retrofit 2000 04/09/2019 EnergyTransferCanada(NOWPembina) Canada SaleCompression 2000 Electric Ariel JGK/6 26/05/2017 EnergyTransferCanada(NOWPembina) Canada Retrofit 2000 04/09/2019 PengrowthEnergy
Corporation Canada SaleCompression 1680 Waukesha L7044GSI Ariel JGK/4 07/06/2017 TesoroLogistics(NOWAndeavor) USA SaleCompression 3000 Electric Frick 11/07/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 300 Electric Ariel JG/4 06/07/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 350 Electric RoFlo 17S 02/08/2017 VelvetEnergyLtd.(NOWSpartanDeltaCorp) Canada Retrofit 1680 Waukesha L7044GSI Ariel JGK/4 23/08/2017 OrlenUpstreamCanadaLtd. Canada SaleCompression 2250 Waukesha P9390GSI Ariel JGD/4 08/09/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 1550 Electric Ariel JGD/4 21/08/2017 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 2370 Caterpillar GE 23/04/2018 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 2370 Caterpillar GE 23/04/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GL Frick NGC400F 20/12/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 26/10/2017 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 20/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 XTOEnergyInc. USA Rental 1680 Waukesha L7044GSI Ariel JGK/4 30/04/2018 ShellCanada Canada SaleCompression 325 Caterpillar G3406TA Ariel JGR/2 16/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 28/02/2018 PembinaPipelineCorporation Canada SaleCompression 850 Electric Ariel JGT/2 12/03/2018 PembinaPipelineCorporation Canada Retrofit 900 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 850 Electric Ariel JGT/2 12/03/2018 PembinaPipelineCorporation Canada Retrofit 900 11/12/2018 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 1150 Caterpillar G3516LE Ariel JGT/2 19/03/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 850 Electric Ariel JGJ/6 19/03/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 850 Electric Ariel JGJ/6 19/03/2018 Schlumberger USA SaleCompression 350 Electric Ariel 25/06/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 Regent
PowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 HaloExplorationLtd. Canada Rental 530 Waukesha H24GL Frick TDSHͲ283S 01/08/2018 BlackbirdEnergyInc.(NOWPipestoneEnergyCorp.) Canada SaleCompression 1900 Waukesha L7044GSI Ariel 14/08/2018 BlackbirdEnergyInc.(NOWPipestoneEnergyCorp.) Canada SaleCompression 1900 Waukesha L7044GSI Ariel 14/08/2018 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 1600 07/08/2018 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 300 Electric Ariel JG/4 25/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 TAQANorthLtd. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 22/06/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 350 Electric Ariel JGJ/2 06/06/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 350 Electric Ariel JGJ/2 06/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3306TA Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 Bapetco Egypt SaleCompression 2250 Waukesha P9390GSI Ariel JGK/4 27/06/2018 Bapetco Egypt SaleCompression 2250 Waukesha P9390GSI Ariel JGK/4 27/06/2018 StormResourcesLtd. Canada SaleCompression 1280 Waukesha L5774LT Frick SGCBͲ3515 25/09/2018 ParamountResourcesLtd. Canada SaleCompression 600 Electric Ariel JGH/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 600 Electric Ariel JGH/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 400 Electric Ariel JGJ/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 400 Electric Ariel JGJ/4 28/09/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 30/10/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 30/10/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GL Frick NGC400F 30/10/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 HaloExplorationLtd. Canada Rental 400 Waukesha F18GL Frick TDSHͲ283L 06/11/2018 ParamountResourcesLtd. Canada SaleCompression 450 Electric RoFlo 28/11/2018 EnhanceEnergyInc. Canada SaleCompression 1400 Electric Ariel 05/12/2018 SevenGenerationsEnergyLtd. Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 21/12/2018 GeneralEnergyRecovery Canada SaleCompression 400 Electric Ariel JGR/4 15/04/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 05/02/2019 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar Ariel 06/03/2019 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar Ariel 06/03/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 740 Waukesha F3514GSI Ariel JGK/2 14/03/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 740 Waukesha F3514GSI Ariel 14/03/2019 HilcorpAlaskaLLC USA SaleProcess 1950 Electric Frick 21/06/2019 AspenleafEnergyLtd.(ALE) Canada Retrofit 350 17/04/2019 PetronasCanada Canada SaleCompression 900 Electric Ariel JGK/2 30/04/2019 CaliberMidstream USA Rental 1150 Caterpillar Frick 23/08/2019 NuVistaEnergyLtd. Canada SaleCompression 300 Electric Ariel JGJ/2 16/05/2019 NuVistaEnergyLtd. Canada SaleCompression 300 Electric Ariel JGJ/2 16/05/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 2250 Waukesha Ariel JGD/4 08/05/2019 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/4 23/05/2019 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/6 23/05/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 MitsuiE&PAustraliaPtyLtd.(MEPAU) Australia SaleCompression 1004 Caterpillar G3512LE Ariel JGT/2 04/07/2019 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOil Corp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 26/05/2021 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 29/10/2019 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 CanadianNaturalResourcesLimited Canada SaleCompression 400 Electric RoFlo 05/11/2019 ImperialOilResourcesLimited Canada SaleCompression 350 Electric Ariel 06/12/2019 HuskyEnergyInc(NowCenovus) Canada SaleCompression 900 Electric Ariel 12/12/2019 OutriggerEnergyLLC USA SaleCompression 1800 Electric Ariel 23/12/2019 OutriggerEnergyLLC USA SaleCompression 1800 Electric Ariel 23/12/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 ConocoPhillipsCanada Canada SaleCompression 800 Electric Ariel JGT/4 28/09/2021 ConocoPhillipsCanada Canada SaleCompression 800 Electric Ariel JGT/4 28/09/2021 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 17/03/2020 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 17/03/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 ZetonInc. USA SaleCompression 300 Electric Ariel JGJ/4 27/09/2021 StormResourcesLtd. Canada SaleCompression 1875 Caterpillar G3606LE Ariel 05/11/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 PetronasCanada Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/04/2021 TAQANorthLtd. Canada SaleCompression 750 Electric Ariel JGJ/4 18/05/2021 AdvantageEnergyLtd. Canada SaleCompression 1300 Electric Ariel 19/05/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC450C 14/07/2021 StrathconaResourcesLtd. Canada Flip 1150 Caterpillar GE 22/07/2021 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/4 25/08/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha Frick 19/10/2021 StrathconaResourcesLtd. Canada SaleCompression 2500 Waukesha P9394GSI 23/09/2021 ATCOEnergySolutionsLtd. Canada SaleCompression 1900 Waukesha Ariel 28/09/2021 ATCOEnergySolutionsLtd. Canada SaleCompression 1900 Waukesha Ariel 28/09/2021 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 18/11/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 22/10/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9390GL 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystems Inc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 NAHelium Canada SaleCompression 350 Electric Ariel JGR/4 17/02/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 28/02/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 28/02/2022 AdvantageEnergyLtd. Canada SaleCompression 5000 Caterpillar G3616LE Ariel KBZ/6 06/04/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 30/03/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 30/03/2022 LeucrottaExploration(NOWCoelacanth) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 28/03/2022 LeucrottaExploration(NOWCoelacanth) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 28/03/2022 AltaGasLtd. Canada SaleCompression 1200 Electric Ariel 29/04/2022 AltaGasLtd. Canada SaleCompression 1200 Electric Ariel 29/04/2022 NAHelium Canada SaleCompression 900 Electric Mycom 21/04/2022 NAHelium Canada SaleCompression 900 Electric Mycom 21/04/2022 WestbrickEnergyLtd. Canada Flip 1680 Waukesha L7044GSI Ariel JGK/4 21/04/2022 WestbrickEnergyLtd. Canada Flip 1680 Waukesha L7044GSI Ariel JGK/4 21/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA Sale Compression 2500 Waukesha P9394GSI 27/04/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 19/05/2022 CenovusEnergyInc. Canada SaleCompression 1900 Waukesha Ariel 19/05/2022 NAHelium Canada SaleCompression 350 Electric Ariel 27/05/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 PacificCanbriamEnergyInc. Canada SaleCompression 2500 Caterpillar Frick 14/06/2022 TundraOil&Gas Canada Flip 350 Electric Ariel 27/06/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 ZetonInc. USA SaleCompression 300 Electric Ariel JGJ/4 27/09/2021 StormResourcesLtd. Canada SaleCompression 1875 Caterpillar G3606LE Ariel 05/11/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 PetronasCanada Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/04/2021 TAQANorthLtd. Canada SaleCompression 750 Electric Ariel JGJ/4 18/05/2021 AdvantageEnergyLtd. Canada SaleCompression 1300 Electric Ariel 19/05/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC450C 14/07/2021 StrathconaResourcesLtd. Canada Flip 1150 Caterpillar GE 22/07/2021 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/4 25/08/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha Frick 19/10/2021 StrathconaResourcesLtd. Canada SaleCompression 2500 Waukesha P9394GSI 23/09/2021 ATCOEnergySolutionsLtd. Canada SaleCompression 1900 Waukesha Ariel 28/09/2021 ATCOEnergySolutionsLtd. Canada SaleCompression 1900 Waukesha Ariel 28/09/2021 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 18/11/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 22/10/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9390GL 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystems Inc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 NAHelium Canada SaleCompression 350 Electric Ariel JGR/4 17/02/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 28/02/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 28/02/2022 AdvantageEnergyLtd. Canada SaleCompression 5000 Caterpillar G3616LE Ariel KBZ/6 06/04/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 30/03/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 30/03/2022 LeucrottaExploration(NOWCoelacanth) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 28/03/2022 LeucrottaExploration(NOWCoelacanth) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 28/03/2022 AltaGasLtd. Canada SaleCompression 1200 Electric Ariel 29/04/2022 AltaGasLtd. Canada SaleCompression 1200 Electric Ariel 29/04/2022 NAHelium Canada SaleCompression 900 Electric Mycom 21/04/2022 NAHelium Canada SaleCompression 900 Electric Mycom 21/04/2022 WestbrickEnergyLtd. Canada Flip 1680 Waukesha L7044GSI Ariel JGK/4 21/04/2022 WestbrickEnergyLtd. Canada Flip 1680 Waukesha L7044GSI Ariel JGK/4 21/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 19/05/2022 CenovusEnergy
Inc. Canada SaleCompression 1900 Waukesha Ariel 19/05/2022 NAHelium Canada SaleCompression 350 Electric Ariel 27/05/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 PacificCanbriamEnergyInc. Canada SaleCompression 2500 Caterpillar Frick 14/06/2022 TundraOil&Gas Canada Flip 350 Electric Ariel 27/06/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CenovusEnergyInc. Canada SaleCompression 1900 Waukesha L7044GSI Ariel 12/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 HammerheadResourcesInc. Canada SaleCompression 300 Electric Ariel JGR/2 20/10/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 1875 Caterpillar G3606LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha Ariel JGJ/2 12/01/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha Ariel JGJ/2 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 NAHelium Canada SaleCompression 400 Electric Ariel JGJ/2 05/01/2023 NAHelium Canada SaleCompression 400 Electric Ariel JGJ/2 05/01/2023 PetronasCanada Canada SaleCompression 2500 Caterpillar Ariel 18/01/2023 ParamountResourcesLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 11/01/2023 ParamountResourcesLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 11/01/2023 NAHelium Canada SaleCompression 300 Electric Frick 17/02/2023 NAHelium Canada SaleCompression 300 Electric Frick 17/02/2023 CoelacanthEnergy
Inc. Canada SaleCompression 3850 Caterpillar Ariel KBZ/4 01/06/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSI Ariel JGD/4 31/03/2023 StrathconaResourcesLtd. Canada SaleCompression 3750 Caterpillar Ariel 29/03/2023 InsigniaEnergyLtd. Canada SaleCompression 1900 Waukesha Ariel 25/05/2023 NAHelium Canada SaleCompression 1500 Electric Ariel 29/05/2023 NAHelium Canada SaleCompression 1500 Electric Ariel 29/05/2023 OXY USA SaleCompression 1600 Electric Ariel 14/07/2023 OXY USA SaleCompression 1600 Electric Ariel 14/07/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 31/07/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 31/07/2023 CanadianNaturalResourcesLimited Canada SaleCompression 1250 Electric Frick SGCͲ2821 09/02/2024 NorthRiverMidstream Canada SaleCompression 2250 30/11/2023 NorthRiverMidstream Canada SaleCompression 2500 Electric Ariel 30/11/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 ParamountResourcesLtd. Canada SaleCompression 1200 Electric Ariel JGJ/4 21/11/2023 ParamountResourcesLtd. Canada SaleCompression 2500 Electric Ariel JGD/4 21/11/2023 ParamountResourcesLtd. Canada SaleCompression 2500 Electric Ariel JGD/4 21/11/2023 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 08/01/2024 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 08/01/2024 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 08/01/2024 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 08/01/2024 NorthRiverMidstream Canada SaleCompression 300 Electric Ariel 30/01/2024 AltaGasLtd. Canada SaleCompression 1900 Electric Ariel 31/03/2024 AltaGasLtd. Canada SaleCompression 1900 Electric Ariel 31/03/2024 ZargonOil&GasLtd. 0 SaleCompression 420 Cummins GD 03/04/2007 CrewEnergyInc. Canada Rental 420 Cummins KTA19 GD 08/05/2014 SIWAPETROLEUMDMCC Pakistan SaleCompression 450 08/12/2008 SummitMidstreamPartners,LLC USA RentalSale 738 Waukesha F3514GSI Ariel JGH/4 27/06/2014 PetrogasEnergy Corp.(NOWAltaGasLtd.) 0 SaleCompression 1478 12/02/2010 ConocoPhillipsCanada 0 SaleCompression 1478 02/02/2010 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 24/03/2010 ADDEMIREL Turkey SaleCompression 400 Caterpillar G3408TA Sullair PC25S 24/03/2010 FerusInc. USA Rental 400 Waukesha F18GSI Ariel JGJ/4 09/09/2014 CrescentPointEnergyCorp. Canada Rental 400 Waukesha F18GL Ariel JGJ/4 01/02/2017 BullMooseCapitalLtd. Canada Flip 400 Waukesha Ariel 14/12/2021 ArtisExplorationLtd. Canada Rental 400 Waukesha F18GL Ariel JGJ/2 31/05/2018 HaloExplorationLtd. Canada Flip 400 Waukesha Ariel 01/04/2022 AnadarkoPetroleumCorporation USA SaleCompression 1380 04/08/2010 AnadarkoPetroleumCorporation USA SaleCompression 690 04/08/2010 S&WEnergySolutionsInc. Venezuela SaleCompression 600 Electric Ariel JGJ/2 04/02/2010 S&WEnergySolutionsInc. Venezuela SaleCompression 600 Electric Ariel JGJ/2 17/02/2010 HuskyEnergyInc(NowCenovus) 0 SaleCompression 740 21/07/2010 HuskyEnergyInc(NowCenovus) Canada SaleCompression 574 21/12/2010 LakustaEnergyServices(1994)Ltd. Canada SaleCompression 1250 08/11/2010 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 03/02/2011 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 03/02/2011 HuskyEnergyInc(NowCenovus) Canada SaleCompression 300 27/01/2011 PetronasDaganganBerhad Malaysia SaleCompression 4735 Caterpillar G3616LE Ariel KBZ/6 29/11/2011 ParamountResourcesLtd. Canada SaleCompression 3550 Caterpillar G3612LE 17/02/2011 ENXCompressors,S.A.deC.V. Mexico SaleCompression 1480 07/04/2011 BlaiseEnergyInc. USA Rental 400 Ariel JGA/4 05/02/2019 EOGResources,Inc. USA Retrofit 670 Caterpillar Ariel 29/07/2015 PegsaLtda. Colombia SaleCompression 530 Waukesha H24GL Ariel JGJ/2 12/08/2015 FerusInc. Canada SaleCompression 325 Caterpillar G3406TA Ariel JGA/4 29/09/2015 SevenGenerationsEnergyLtd. Canada Rental 1450 09/07/2019 SpectraEnergyCanadaGasTransmissionInc.(NOWEnbridgeInc.) Canada SaleCompression 3750 Caterpillar G3512LE Ariel JGC/4 14/10/2015 EOGResources,Inc. USA Retrofit 670 Caterpillar Ariel 10/11/2015 EOGResources,Inc. USA Retrofit 670 Caterpillar G3508LE Ariel JGJ/4 10/11/2015 ARCResourcesLtd. Canada SaleCompression 600 Electric Ariel JGJ/2 16/12/2015 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 400 Electric Ariel JGR/4 22/12/2015 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 300 Electric RoFlo 19S 22/12/2015 UnconventionalGasResourcesCanadaOperatingInc.(NOWPaintedPony) Canada Rental 530 Waukesha H24GL Ariel JGJ/2 07/01/2016 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 23/02/2016 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 1250 Waukesha L5774LT Frick SGCͲ2821 23/02/2016 WBIEnergyMidstream USA SaleCompression 1775 Caterpillar G3606LE Ariel JGK/4 07/06/2016 WBIEnergyMidstream USA SaleCompression 750 Electric Ariel JGT/2 07/06/2016 WBIEnergyMidstream USA SaleCompression 1380 Caterpillar G3516BLE Ariel JGT/4 07/06/2016 BlackbirdEnergyInc.(NOWPipestoneEnergyCorp.) Canada SaleCompression 300 Electric Ariel JG/4 07/06/2016 PetrogasEnergyCorp.(NOWAltaGasLtd.) Canada SaleCompression 600 Caterpillar Frick SGCBͲ3519 11/07/2016 PetrogasEnergyCorp.(NOWAltaGasLtd.) Canada SaleCompression 600 Caterpillar Frick SGCBͲ3519 11/07/2016 AthabascaOilCorporation Canada SaleCompression 2445 Caterpillar G3608LE Ariel JGC/4 17/08/2016 AthabascaOilCorporation Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/6 17/08/2016 PennWestPetroleumLtd.(NOWObsidianEnergyLtd.) Canada SaleCompression 325 Caterpillar G3406TA Frick TDSHͲ233XL 09/12/2016 PennWestPetroleumLtd.(NOWObsidianEnergyLtd.) Canada SaleCompression 325 Caterpillar G3406TA RoFlo 4CC 09/12/2016 OvintivCanadaULC(EncanaCorporation) Canada Rental 530 Waukesha H24GL Ariel JGJ/2 07/02/2018 NuVistaEnergyLtd. Canada Rental 530 09/07/2019
PembinaPipelineCorporation Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 07/09/2016 Pembina
PipelineCorporation Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 07/09/2016 CanadianNaturalResourcesLimited Canada MajorProject 400 Electric RoFlo 05/11/2019 VoltaGrid USA SaleCompression 700 Electric Ariel JGA/6 07/07/2022 VoltaGrid USA SaleCompression 700 Electric Ariel JGA/6 07/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGC/4 24/02/2023 BlaiseEnergyInc. USA Rental 400 Ariel JGA/4 05/02/2019 EOGResources,Inc. USA Retrofit 670 Caterpillar Ariel 29/07/2015 PegsaLtda. Colombia SaleCompression 530 Waukesha H24GL Ariel JGJ/2 12/08/2015 FerusInc. Canada SaleCompression 325 Caterpillar G3406TA Ariel JGA/4 29/09/2015 SevenGenerationsEnergyLtd. Canada Rental 1450 09/07/2019 SpectraEnergyCanadaGasTransmissionInc.(NOWEnbridgeInc.) Canada SaleCompression 3750 Caterpillar G3512LE Ariel JGC/4 14/10/2015 EOGResources,Inc. USA Retrofit 670 Caterpillar Ariel 10/11/2015 EOGResources,Inc. USA Retrofit 670 Caterpillar G3508LE Ariel JGJ/4 10/11/2015 ARCResourcesLtd. Canada SaleCompression 600 Electric Ariel JGJ/2 16/12/2015 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 400 Electric Ariel JGR/4 22/12/2015 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 300 Electric RoFlo 19S 22/12/2015 UnconventionalGasResourcesCanadaOperatingInc.(NOWPaintedPony) Canada Rental 530 Waukesha H24GL Ariel JGJ/2 07/01/2016 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 23/02/2016 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 1250 Waukesha L5774LT Frick SGCͲ2821 23/02/2016 WBIEnergyMidstream USA SaleCompression 1775 Caterpillar G3606LE Ariel JGK/4 07/06/2016 WBIEnergyMidstream USA SaleCompression 750 Electric Ariel JGT/2 07/06/2016 WBIEnergyMidstream USA SaleCompression 1380 Caterpillar G3516BLE Ariel JGT/4 07/06/2016 BlackbirdEnergyInc.(NOWPipestoneEnergyCorp.) Canada SaleCompression 300 Electric Ariel JG/4 07/06/2016 PetrogasEnergyCorp.(NOWAltaGasLtd.) Canada SaleCompression 600 Caterpillar Frick SGCBͲ3519 11/07/2016 PetrogasEnergyCorp.(NOWAltaGasLtd.) Canada SaleCompression 600 Caterpillar Frick SGCBͲ3519 11/07/2016 AthabascaOilCorporation Canada SaleCompression 2445 Caterpillar G3608LE Ariel JGC/4 17/08/2016 AthabascaOilCorporation Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/6 17/08/2016 PennWestPetroleumLtd.(NOWObsidianEnergyLtd.) Canada SaleCompression 325 Caterpillar G3406TA Frick TDSHͲ233XL 09/12/2016 PennWestPetroleumLtd.(NOWObsidianEnergyLtd.) Canada SaleCompression 325 Caterpillar G3406TA RoFlo 4CC 09/12/2016 OvintivCanadaULC(EncanaCorporation) Canada Rental 530 Waukesha H24GL Ariel JGJ/2 07/02/2018 NuVistaEnergyLtd. Canada Rental 530 09/07/2019
PembinaPipelineCorporation Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 07/09/2016 Pembina
PipelineCorporation Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 07/09/2016 CanadianNaturalResourcesLimited Canada MajorProject 400 Electric RoFlo 05/11/2019 VoltaGrid USA SaleCompression 700 Electric Ariel JGA/6 07/07/2022 VoltaGrid USA SaleCompression 700 Electric Ariel JGA/6 07/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel 09/11/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGC/4 24/02/2023 ŽŵƉĂƐƐ>ĂƌŐĞ,W;ϯϬϬ,WĂŶĚĂďŽǀĞͿZĞĨĞƌĞŶĐĞ>ŝƐƚ
AccountName:AccountName LocationCountry/International Market HP Driver Manufacturer Driver Model CompressorManufacturer Compressor Model OrderDate PecanPipelineCompany USA Rental 810 Caterpillar G3512LE GE 12/10/2016 EnergyTransferCanada(NOWPembina) Canada SaleCompression 1680 Waukesha L7044GSI Frick SGCBͲ3519 24/11/2016 EnergyTransferCanada(NOWPembina) Canada SaleCompression 1680 Waukesha L7044GSI Frick SGCBͲ3519 25/01/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 04/11/2016 E.S.FoxLtd. Canada SaleCompression 440 Electric Frick SGCͲ2313 15/11/2016 MeritageMidstreamServices Canada SaleProcess 400 Electric Ariel JGJ/2 09/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGD/4 10/01/2017 CSVMidstreamSolutions Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBU/4 10/01/2017 StormResourcesLtd. Canada SaleCompression 3550 Caterpillar G3612LE Ariel KBU/4 22/06/2017 CSVMidstreamSolutions Canada SaleCompression 400 Electric Ariel 07/03/2017 CSVMidstreamSolutions Canada SaleCompression 400 Electric RoFlo 07/03/2017 AthabascaOilCorporation Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/6 16/03/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 600 Electric RoFlo 03/05/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 18/04/2017 EnergyTransferCanada(NOWPembina) Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 27/04/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 1300 Electric Ariel JGE/4 05/05/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 1300 Electric Ariel JGE/4 05/05/2017 EnergyTransferCanada(NOWPembina) Canada SaleCompression 2000 Electric Ariel JGK/6 26/05/2017 EnergyTransferCanada(NOWPembina) Canada Retrofit 2000 04/09/2019 EnergyTransferCanada(NOWPembina) Canada SaleCompression 2000 Electric Ariel JGK/6 26/05/2017 EnergyTransferCanada(NOWPembina) Canada Retrofit 2000 04/09/2019 PengrowthEnergy
Corporation Canada SaleCompression 1680 Waukesha L7044GSI Ariel JGK/4 07/06/2017 TesoroLogistics(NOWAndeavor) USA SaleCompression 3000 Electric Frick 11/07/2017 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 300 Electric Ariel JG/4 06/07/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 350 Electric RoFlo 17S 02/08/2017 VelvetEnergyLtd.(NOWSpartanDeltaCorp) Canada Retrofit 1680 Waukesha L7044GSI Ariel JGK/4 23/08/2017 OrlenUpstreamCanadaLtd. Canada SaleCompression 2250 Waukesha P9390GSI Ariel JGD/4 08/09/2017 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 1550 Electric Ariel JGD/4 21/08/2017 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 2370 Caterpillar GE 23/04/2018 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 2370 Caterpillar GE 23/04/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GL Frick NGC400F 20/12/2017 SevenGenerationsEnergyLtd. Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 26/10/2017 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 20/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 22/12/2017 XTOEnergyInc. USA Rental 1680 Waukesha L7044GSI Ariel JGK/4 30/04/2018 ShellCanada Canada SaleCompression 325 Caterpillar G3406TA Ariel JGR/2 16/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 28/02/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 28/02/2018 PembinaPipelineCorporation Canada SaleCompression 850 Electric Ariel JGT/2 12/03/2018 PembinaPipelineCorporation Canada Retrofit 900 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 850 Electric Ariel JGT/2 12/03/2018 PembinaPipelineCorporation Canada Retrofit 900 11/12/2018 OvintivCanadaULC(EncanaCorporation) Canada SaleCompression 1150 Caterpillar G3516LE Ariel JGT/2 19/03/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 850 Electric Ariel JGJ/6 19/03/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 850 Electric Ariel JGJ/6 19/03/2018 Schlumberger USA SaleCompression 350 Electric Ariel 25/06/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 PembinaPipelineCorporation Canada SaleCompression 1300 Electric Ariel JGT/4 27/04/2018 PembinaPipelineCorporation Canada Retrofit 1050 11/12/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L5794GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 RegentPowerandCompression Canada Retrofit 1380 Waukesha L7044GSI 13/06/2018 HaloExplorationLtd. Canada Rental 530 Waukesha H24GL Frick TDSHͲ283S 01/08/2018 BlackbirdEnergyInc.(NOWPipestoneEnergyCorp.) Canada SaleCompression 1900 Waukesha L7044GSI Ariel 14/08/2018 BlackbirdEnergyInc.(NOWPipestoneEnergyCorp.) Canada SaleCompression 1900 Waukesha L7044GSI Ariel 14/08/2018 TidewaterMidstreamandInfrastructureLtd. Canada Retrofit 1600 07/08/2018 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 300 Electric Ariel JG/4 25/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 23/07/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 ElevationMidstream USA SaleCompression 350 Electric RoFlo 19LE 30/10/2018 TAQANorthLtd. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 22/06/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 350 Electric Ariel JGJ/2 06/06/2018 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 350 Electric Ariel JGJ/2 06/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3306TA Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 25/06/2018 Bapetco Egypt SaleCompression 2250 Waukesha P9390GSI Ariel JGK/4 27/06/2018 Bapetco Egypt SaleCompression 2250 Waukesha P9390GSI Ariel JGK/4 27/06/2018 StormResourcesLtd. Canada SaleCompression 1280 Waukesha L5774LT Frick SGCBͲ3515 25/09/2018 ParamountResourcesLtd. Canada SaleCompression 600 Electric Ariel JGH/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 600 Electric Ariel JGH/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 400 Electric Ariel JGJ/4 28/09/2018 ParamountResourcesLtd. Canada SaleCompression 400 Electric Ariel JGJ/4 28/09/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 30/10/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 30/10/2018 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GL Frick NGC400F 30/10/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 ShellCanada Canada SaleCompression 400 Waukesha Ariel 06/12/2018 HaloExplorationLtd. Canada Rental 400 Waukesha F18GL Frick TDSHͲ283L 06/11/2018 ParamountResourcesLtd. Canada SaleCompression 450 Electric RoFlo 28/11/2018 EnhanceEnergyInc. Canada SaleCompression 1400 Electric Ariel 05/12/2018 SevenGenerationsEnergyLtd. Canada SaleCompression 3750 Caterpillar G3612LE Ariel JGC/4 21/12/2018 GeneralEnergyRecovery Canada SaleCompression 400 Electric Ariel JGR/4 15/04/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 05/02/2019 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar Ariel 06/03/2019 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar Ariel 06/03/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 740 Waukesha F3514GSI Ariel JGK/2 14/03/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 740 Waukesha F3514GSI Ariel 14/03/2019 HilcorpAlaskaLLC USA SaleProcess 1950 Electric Frick 21/06/2019 AspenleafEnergyLtd.(ALE) Canada Retrofit 350 17/04/2019 PetronasCanada Canada SaleCompression 900 Electric Ariel JGK/2 30/04/2019 CaliberMidstream USA Rental 1150 Caterpillar Frick 23/08/2019 NuVistaEnergyLtd. Canada SaleCompression 300 Electric Ariel JGJ/2 16/05/2019 NuVistaEnergyLtd. Canada SaleCompression 300 Electric Ariel JGJ/2 16/05/2019 OrlenUpstreamCanadaLtd. Canada SaleCompression 2250 Waukesha Ariel JGD/4 08/05/2019 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/4 23/05/2019 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/6 23/05/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 18/06/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 ONEOK,Inc. USA SaleCompression 2500 Electric Ariel 02/07/2019 MitsuiE&PAustraliaPtyLtd.(MEPAU) Australia SaleCompression 1004 Caterpillar G3512LE Ariel JGT/2 04/07/2019 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOil Corp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/07/2020 BlackSwanEnergy(NOWTourmalineOilCorp.) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 26/05/2021 AdvantageEnergyLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 29/10/2019 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 28/11/2019 CanadianNaturalResourcesLimited Canada SaleCompression 400 Electric RoFlo 05/11/2019 ImperialOilResourcesLimited Canada SaleCompression 350 Electric Ariel 06/12/2019 HuskyEnergyInc(NowCenovus) Canada SaleCompression 900 Electric Ariel 12/12/2019 OutriggerEnergyLLC USA SaleCompression 1800 Electric Ariel 23/12/2019 OutriggerEnergyLLC USA SaleCompression 1800 Electric Ariel 23/12/2019 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 NorthbaseFinanceInc. USA SaleCompression 2500 Waukesha P9394GSIS5 06/01/2020 ConocoPhillipsCanada Canada SaleCompression 800 Electric Ariel JGT/4 28/09/2021 ConocoPhillipsCanada Canada SaleCompression 800 Electric Ariel JGT/4 28/09/2021 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 17/03/2020 ShellCanada Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 17/03/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 03/04/2020 ZetonInc. USA SaleCompression 300 Electric Ariel JGJ/4 27/09/2021 StormResourcesLtd. Canada SaleCompression 1875 Caterpillar G3606LE Ariel 05/11/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSIS5 07/12/2020 PetronasCanada Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 20/04/2021 TAQANorthLtd. Canada SaleCompression 750 Electric Ariel JGJ/4 18/05/2021 AdvantageEnergyLtd. Canada SaleCompression 1300 Electric Ariel 19/05/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC450C 14/07/2021 StrathconaResourcesLtd. Canada Flip 1150 Caterpillar GE 22/07/2021 ONEOK,Inc. USA SaleCompression 2370 Caterpillar G3608LE Ariel JGC/4 25/08/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha Frick 19/10/2021 StrathconaResourcesLtd. Canada SaleCompression 2500 Waukesha P9394GSI 23/09/2021 ATCOEnergySolutionsLtd. Canada SaleCompression 1900 Waukesha Ariel 28/09/2021 ATCOEnergySolutionsLtd. Canada SaleCompression 1900 Waukesha Ariel 28/09/2021 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 18/11/2021 CrestwoodMidstreamPartners USA SaleCompression 1480 Waukesha L7042GSI Frick NGC400F 22/10/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9390GL 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystems Inc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 03/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 10/12/2021 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 GenaltaPowerInc. Canada SaleCompression 2500 Waukesha 14/01/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSIS5 Ariel JGD/4 16/02/2022 NAHelium Canada SaleCompression 350 Electric Ariel JGR/4 17/02/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 28/02/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 28/02/2022 AdvantageEnergyLtd. Canada SaleCompression 5000 Caterpillar G3616LE Ariel KBZ/6 06/04/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 30/03/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 30/03/2022 LeucrottaExploration(NOWCoelacanth) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 28/03/2022 LeucrottaExploration(NOWCoelacanth) Canada SaleCompression 3750 Caterpillar G3612LE Ariel KBZ/4 28/03/2022 AltaGasLtd. Canada SaleCompression 1200 Electric Ariel 29/04/2022 AltaGasLtd. Canada SaleCompression 1200 Electric Ariel 29/04/2022 NAHelium Canada SaleCompression 900 Electric Mycom 21/04/2022 NAHelium Canada SaleCompression 900 Electric Mycom 21/04/2022 WestbrickEnergyLtd. Canada Flip 1680 Waukesha L7044GSI Ariel JGK/4 21/04/2022 WestbrickEnergyLtd. Canada Flip 1680 Waukesha L7044GSI Ariel JGK/4 21/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 27/04/2022 CrusoeEnergySystemsInc. USA Sale Compression 2500 Waukesha P9394GSI 27/04/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar G3608LE Ariel JGC/4 19/05/2022 CenovusEnergyInc. Canada SaleCompression 1900 Waukesha Ariel 19/05/2022 NAHelium Canada SaleCompression 350 Electric Ariel 27/05/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 VoltaGrid USA SaleProcess 350 Electric Frick 08/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 HammerheadResourcesInc. Canada SaleCompression 2500 Caterpillar Ariel 02/06/2022 PacificCanbriamEnergyInc. Canada SaleCompression 2500 Caterpillar Frick 14/06/2022 TundraOil&Gas Canada Flip 350 Electric Ariel 27/06/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 VoltaGrid USA SaleCompression 600 Electric Ariel JGJ/4 21/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CenovusEnergyInc. Canada SaleCompression 1900 Waukesha L7044GSI Ariel 12/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 HammerheadResourcesInc. Canada SaleCompression 300 Electric Ariel JGR/2 20/10/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 1875 Caterpillar G3606LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha Ariel JGJ/2 12/01/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha Ariel JGJ/2 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 NAHelium Canada SaleCompression 400 Electric Ariel JGJ/2 05/01/2023 NAHelium Canada SaleCompression 400 Electric Ariel JGJ/2 05/01/2023 PetronasCanada Canada SaleCompression 2500 Caterpillar Ariel 18/01/2023 ParamountResourcesLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 11/01/2023 ParamountResourcesLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 11/01/2023 NAHelium Canada SaleCompression 300 Electric Frick 17/02/2023 NAHelium Canada SaleCompression 300 Electric Frick 17/02/2023 CoelacanthEnergy
Inc. Canada SaleCompression 3850 Caterpillar Ariel KBZ/4 01/06/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSI Ariel JGD/4 31/03/2023 StrathconaResourcesLtd. Canada SaleCompression 3750 Caterpillar Ariel 29/03/2023 InsigniaEnergyLtd. Canada SaleCompression 1900 Waukesha Ariel 25/05/2023 NAHelium Canada SaleCompression 1500 Electric Ariel 29/05/2023 NAHelium Canada SaleCompression 1500 Electric Ariel 29/05/2023 OXY USA SaleCompression 1600 Electric Ariel 14/07/2023 OXY USA SaleCompression 1600 Electric Ariel 14/07/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 31/07/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 31/07/2023 CanadianNaturalResourcesLimited Canada SaleCompression 1250 Electric Frick SGCͲ2821 09/02/2024 NorthRiverMidstream Canada SaleCompression 2250 30/11/2023 NorthRiverMidstream Canada SaleCompression 2500 Electric Ariel 30/11/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 ParamountResourcesLtd. Canada SaleCompression 1200 Electric Ariel JGJ/4 21/11/2023 ParamountResourcesLtd. Canada SaleCompression 2500 Electric Ariel JGD/4 21/11/2023 ParamountResourcesLtd. Canada SaleCompression 2500 Electric Ariel JGD/4 21/11/2023 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 08/01/2024 TidewaterMidstreamandInfrastructure Ltd. Canada SaleCompression 6500 Electric Ariel KBZ/6 08/01/2024 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 08/01/2024 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 08/01/2024 NorthRiverMidstream Canada SaleCompression 300 Electric Ariel 30/01/2024 AltaGasLtd. Canada SaleCompression 1900 Electric Ariel 31/03/2024 AltaGasLtd. Canada SaleCompression 1900 Electric Ariel 31/03/2024 ZargonOil&GasLtd. 0 SaleCompression 420 Cummins GD 03/04/2007 CrewEnergyInc. Canada Rental 420 Cummins KTA19 GD 08/05/2014 SIWAPETROLEUMDMCC Pakistan SaleCompression 450 08/12/2008 SummitMidstreamPartners,LLC USA RentalSale 738 Waukesha F3514GSI Ariel JGH/4 27/06/2014 PetrogasEnergyCorp.(NOWAltaGasLtd.) 0 SaleCompression 1478 12/02/2010 ConocoPhillipsCanada 0 SaleCompression 1478 02/02/2010 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 24/03/2010 ADDEMIREL Turkey SaleCompression 400 Caterpillar G3408TA Sullair PC25S 24/03/2010 FerusInc. USA Rental 400 Waukesha F18GSI Ariel JGJ/4 09/09/2014 CrescentPointEnergyCorp. Canada Rental 400 Waukesha F18GL Ariel JGJ/4 01/02/2017 BullMooseCapitalLtd. Canada Flip 400 Waukesha Ariel 14/12/2021 ArtisExplorationLtd. Canada Rental 400 Waukesha F18GL Ariel JGJ/2 31/05/2018 HaloExplorationLtd. Canada Flip 400 Waukesha Ariel 01/04/2022 AnadarkoPetroleumCorporation USA SaleCompression 1380 04/08/2010 AnadarkoPetroleumCorporation USA SaleCompression 690 04/08/2010 S&WEnergySolutionsInc. Venezuela SaleCompression 600 Electric Ariel JGJ/2 04/02/2010 S&WEnergySolutionsInc. Venezuela SaleCompression 600 Electric Ariel JGJ/2 17/02/2010 HuskyEnergyInc(NowCenovus) 0 SaleCompression 740 21/07/2010 HuskyEnergyInc(NowCenovus) Canada SaleCompression 574 21/12/2010 LakustaEnergyServices(1994)Ltd. Canada SaleCompression 1250 08/11/2010 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 03/02/2011 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 03/02/2011 HuskyEnergyInc(NowCenovus) Canada SaleCompression 300 27/01/2011 PetronasDaganganBerhad Malaysia SaleCompression 4735 Caterpillar G3616LE Ariel KBZ/6 29/11/2011 ParamountResourcesLtd. Canada SaleCompression 3550 Caterpillar G3612LE 17/02/2011 ENXCompressors,S.A.deC.V. Mexico SaleCompression 1480 07/04/2011 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CenovusEnergyInc. Canada SaleCompression 1900 Waukesha L7044GSI Ariel 12/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 HammerheadResourcesInc. Canada SaleCompression 300 Electric Ariel JGR/2 20/10/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 1875 Caterpillar G3606LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha Ariel JGJ/2 12/01/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha Ariel JGJ/2 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 NAHelium Canada SaleCompression 400 Electric Ariel JGJ/2 05/01/2023 NAHelium Canada SaleCompression 400 Electric Ariel JGJ/2 05/01/2023 PetronasCanada Canada SaleCompression 2500 Caterpillar Ariel 18/01/2023 ParamountResourcesLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 11/01/2023 ParamountResourcesLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 11/01/2023 NAHelium Canada SaleCompression 300 Electric Frick 17/02/2023 NAHelium Canada SaleCompression 300 Electric Frick 17/02/2023 CoelacanthEnergy
Inc. Canada SaleCompression 3850 Caterpillar Ariel KBZ/4 01/06/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSI Ariel JGD/4 31/03/2023 StrathconaResourcesLtd. Canada SaleCompression 3750 Caterpillar Ariel 29/03/2023 InsigniaEnergyLtd. Canada SaleCompression 1900 Waukesha Ariel 25/05/2023 NAHelium Canada SaleCompression 1500 Electric Ariel 29/05/2023 NAHelium Canada SaleCompression 1500 Electric Ariel 29/05/2023 OXY USA SaleCompression 1600 Electric Ariel 14/07/2023 OXY USA SaleCompression 1600 Electric Ariel 14/07/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 31/07/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 31/07/2023 CanadianNaturalResourcesLimited Canada SaleCompression 1250 Electric Frick SGCͲ2821 09/02/2024 NorthRiverMidstream Canada SaleCompression 2250 30/11/2023 NorthRiverMidstream Canada SaleCompression 2500 Electric Ariel 30/11/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 ParamountResourcesLtd. Canada SaleCompression 1200 Electric Ariel JGJ/4 21/11/2023 ParamountResourcesLtd. Canada SaleCompression 2500 Electric Ariel JGD/4 21/11/2023 ParamountResourcesLtd. Canada SaleCompression 2500 Electric Ariel JGD/4 21/11/2023 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 08/01/2024 TidewaterMidstreamandInfrastructure Ltd. Canada SaleCompression 6500 Electric Ariel KBZ/6 08/01/2024 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 08/01/2024 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 08/01/2024 NorthRiverMidstream Canada SaleCompression 300 Electric Ariel 30/01/2024 AltaGasLtd. Canada SaleCompression 1900 Electric Ariel 31/03/2024 AltaGasLtd. Canada SaleCompression 1900 Electric Ariel 31/03/2024 ZargonOil&GasLtd. 0 SaleCompression 420 Cummins GD 03/04/2007 CrewEnergyInc. Canada Rental 420 Cummins KTA19 GD 08/05/2014 SIWAPETROLEUMDMCC Pakistan SaleCompression 450 08/12/2008 SummitMidstreamPartners,LLC USA RentalSale 738 Waukesha F3514GSI Ariel JGH/4 27/06/2014 PetrogasEnergyCorp.(NOWAltaGasLtd.) 0 SaleCompression 1478 12/02/2010 ConocoPhillipsCanada 0 SaleCompression 1478 02/02/2010 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 24/03/2010 ADDEMIREL Turkey SaleCompression 400 Caterpillar G3408TA Sullair PC25S 24/03/2010 FerusInc. USA Rental 400 Waukesha F18GSI Ariel JGJ/4 09/09/2014 CrescentPointEnergyCorp. Canada Rental 400 Waukesha F18GL Ariel JGJ/4 01/02/2017 BullMooseCapitalLtd. Canada Flip 400 Waukesha Ariel 14/12/2021 ArtisExplorationLtd. Canada Rental 400 Waukesha F18GL Ariel JGJ/2 31/05/2018 HaloExplorationLtd. Canada Flip 400 Waukesha Ariel 01/04/2022 AnadarkoPetroleumCorporation USA SaleCompression 1380 04/08/2010 AnadarkoPetroleumCorporation USA SaleCompression 690 04/08/2010 S&WEnergySolutionsInc. Venezuela SaleCompression 600 Electric Ariel JGJ/2 04/02/2010 S&WEnergySolutionsInc. Venezuela SaleCompression 600 Electric Ariel JGJ/2 17/02/2010 HuskyEnergyInc(NowCenovus) 0 SaleCompression 740 21/07/2010 HuskyEnergyInc(NowCenovus) Canada SaleCompression 574 21/12/2010 LakustaEnergyServices(1994)Ltd. Canada SaleCompression 1250 08/11/2010 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 03/02/2011 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 03/02/2011 HuskyEnergyInc(NowCenovus) Canada SaleCompression 300 27/01/2011 PetronasDaganganBerhad Malaysia SaleCompression 4735 Caterpillar G3616LE Ariel KBZ/6 29/11/2011 ParamountResourcesLtd. Canada SaleCompression 3550 Caterpillar G3612LE 17/02/2011 ENXCompressors,S.A.deC.V. Mexico SaleCompression 1480 07/04/2011 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 24/07/2022 CenovusEnergyInc. Canada SaleCompression 1900 Waukesha L7044GSI Ariel 12/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2022 HammerheadResourcesInc. Canada SaleCompression 300 Electric Ariel JGR/2 20/10/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 1875 Caterpillar G3606LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 CSVMidstreamSolutions Canada SaleCompression 2500 Caterpillar G3608LE Ariel 14/11/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 WhitecapResourcesInc. Canada SaleCompression 1480 Waukesha L7044GSI Ariel 16/12/2022 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha Ariel JGJ/2 12/01/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha Ariel JGJ/2 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 PetronasCanada Canada SaleCompression 3750 Caterpillar Ariel 12/01/2023 NAHelium Canada SaleCompression 400 Electric Ariel JGJ/2 05/01/2023 NAHelium Canada SaleCompression 400 Electric Ariel JGJ/2 05/01/2023 PetronasCanada Canada SaleCompression 2500 Caterpillar Ariel 18/01/2023 ParamountResourcesLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 11/01/2023 ParamountResourcesLtd. Canada SaleCompression 3875 Caterpillar G3612LE Ariel KBZ/4 11/01/2023 NAHelium Canada SaleCompression 300 Electric Frick 17/02/2023 NAHelium Canada SaleCompression 300 Electric Frick 17/02/2023 CoelacanthEnergy
Inc. Canada SaleCompression 3850 Caterpillar Ariel KBZ/4 01/06/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 28/04/2023 ONEOK,Inc. USA SaleCompression 2500 Waukesha P9394GSI Ariel JGD/4 31/03/2023 StrathconaResourcesLtd. Canada SaleCompression 3750 Caterpillar Ariel 29/03/2023 InsigniaEnergyLtd. Canada SaleCompression 1900 Waukesha Ariel 25/05/2023 NAHelium Canada SaleCompression 1500 Electric Ariel 29/05/2023 NAHelium Canada SaleCompression 1500 Electric Ariel 29/05/2023 OXY USA SaleCompression 1600 Electric Ariel 14/07/2023 OXY USA SaleCompression 1600 Electric Ariel 14/07/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 31/07/2023 CrescentPointEnergyCorp. Canada SaleCompression 400 Waukesha F18GL Ariel JGJ/2 31/07/2023 CanadianNaturalResourcesLimited Canada SaleCompression 1250 Electric Frick SGCͲ2821 09/02/2024 NorthRiverMidstream Canada SaleCompression 2250 30/11/2023 NorthRiverMidstream Canada SaleCompression 2500 Electric Ariel 30/11/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 CrusoeEnergySystemsInc. USA SaleCompression 2500 Waukesha P9394GSI 13/10/2023 ParamountResourcesLtd. Canada SaleCompression 1200 Electric Ariel JGJ/4 21/11/2023 ParamountResourcesLtd. Canada SaleCompression 2500 Electric Ariel JGD/4 21/11/2023 ParamountResourcesLtd. Canada SaleCompression 2500 Electric Ariel JGD/4 21/11/2023 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 6500 Electric Ariel KBZ/6 08/01/2024 TidewaterMidstreamandInfrastructure Ltd. Canada SaleCompression 6500 Electric Ariel KBZ/6 08/01/2024 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 08/01/2024 TidewaterMidstreamandInfrastructureLtd. Canada SaleCompression 5500 Electric Ariel KBZ/4 08/01/2024 NorthRiverMidstream Canada SaleCompression 300 Electric Ariel 30/01/2024 AltaGasLtd. Canada SaleCompression 1900 Electric Ariel 31/03/2024 AltaGasLtd. Canada SaleCompression 1900 Electric Ariel 31/03/2024 ZargonOil&GasLtd. 0 SaleCompression 420 Cummins GD 03/04/2007 CrewEnergyInc. Canada Rental 420 Cummins KTA19 GD 08/05/2014 SIWAPETROLEUMDMCC Pakistan SaleCompression 450 08/12/2008 SummitMidstreamPartners,LLC USA RentalSale 738 Waukesha F3514GSI Ariel JGH/4 27/06/2014 PetrogasEnergyCorp.(NOWAltaGasLtd.) 0 SaleCompression 1478 12/02/2010 ConocoPhillipsCanada 0 SaleCompression 1478 02/02/2010 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 24/03/2010 ADDEMIREL Turkey SaleCompression 400 Caterpillar G3408TA Sullair PC25S 24/03/2010 FerusInc. USA Rental 400 Waukesha F18GSI Ariel JGJ/4 09/09/2014 CrescentPointEnergyCorp. Canada Rental 400 Waukesha F18GL Ariel JGJ/4 01/02/2017 BullMooseCapitalLtd. Canada Flip 400 Waukesha Ariel 14/12/2021 ArtisExplorationLtd. Canada Rental 400 Waukesha F18GL Ariel JGJ/2 31/05/2018 HaloExplorationLtd. Canada Flip 400 Waukesha Ariel 01/04/2022 AnadarkoPetroleumCorporation USA SaleCompression 1380 04/08/2010 AnadarkoPetroleumCorporation USA SaleCompression 690 04/08/2010 S&WEnergySolutionsInc. Venezuela SaleCompression 600 Electric Ariel JGJ/2 04/02/2010 S&WEnergySolutionsInc. Venezuela SaleCompression 600 Electric Ariel JGJ/2 17/02/2010 HuskyEnergyInc(NowCenovus) 0 SaleCompression 740 21/07/2010 HuskyEnergyInc(NowCenovus) Canada SaleCompression 574 21/12/2010 LakustaEnergyServices(1994)Ltd. Canada SaleCompression 1250 08/11/2010 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 03/02/2011 ADDEMIREL Turkey SaleCompression 325 Caterpillar G3406TA Sullair PC20L 03/02/2011 HuskyEnergyInc(NowCenovus) Canada SaleCompression 300 27/01/2011 PetronasDaganganBerhad Malaysia SaleCompression 4735 Caterpillar G3616LE Ariel KBZ/6 29/11/2011 ParamountResourcesLtd. Canada SaleCompression 3550 Caterpillar G3612LE 17/02/2011 ENXCompressors,S.A.deC.V. Mexico SaleCompression 1480 07/04/2011

Roseville City CouncilApril 2, 2025

Roseville City Council
April 2, 2025