January 2021
EXHIBIT E Page 104 of 130 EXHIBIT 2 948
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
1. DISADVANTAGED BUSINESS ENTERPRISES (DBE)
The contractor, subrecipient or subcontractor shall take necessary and reasonable steps to ensure that DBEs have opportunity to participate in the contract (49 CFR 26). To ensure equal participation of DBEs provided in 49 CFR 26.5, the Agency shows a contract goal for DBEs. The prime contractor shall make work available to DBEs and select work parts consistent with available DBE subcontractors and suppliers.
The prime contractor shall meet the DBE goal shown elsewhere in these special provisions or demonstrate that they made adequate good faith efforts to meet this goal.
It is the prime contractor’s responsibility to verify that the DBE firm is certified as DBE at date of bid opening and document the record by printing out the California Unified Certification Program (CUCP) data for each DBE firm. A list of DBEs certified by the CUCP can be found here.
All DBE participation will count toward the California Department of Transportation’s federally mandated statewide overall DBE goal.
Credit for materials or supplies the prime contractor purchases from DBEs counts towards the goal in the following manner:
• 100 percent counts if the materials or supplies are obtained from a DBE manufacturer. • 60 percent counts if the materials or supplies are obtained from a DBE regular dealer. • Only fees, commissions, and charges for assistance in the procurement and delivery of materials or supplies count if obtained from a DBE that is neither a manufacturer nor regular dealer. 49 CFR
26.55 defines "manufacturer" and "regular dealer."
The prime contractor receives credit towards the goal if they employ a DBE trucking company that performs a commercially useful function as defined in 49 CFR 26.55(d)(1) as follows:
• The DBE must be responsible for the management and supervision of the entire trucking operation for which it is responsible on a particular contract, and there cannot be a contrived arrangement for the purpose of meeting DBE goals.
• The DBE must itself own and operate at least one fully licensed, insured, and operational truck used on the contract.
• The DBE receives credit for the total value of the transportation services it provides on the Contract using trucks it owns, insures, and operates using drivers it employs. • The DBE may lease trucks from another DBE firm, including an owner-operator who is certified as a DBE. The DBE who leases trucks from another DBE receives credit for the total value of the transportation services the lessee DBE provides on the Contract. • The DBE may lease trucks without drivers from a non-DBE truck leasing company. If the DBE leases trucks from a non-DBE truck leasing company and uses its own employees as drivers, it is entitled to credit for the total value of these hauling services. • A lease must indicate that the DBE has exclusive use of and control over the truck. This does not preclude the leased truck from working for others during the term of the lease with the consent of the DBE, so long as the lease gives the DBE absolute priority for use of the leased truck. Leased trucks must display the name and identification number of the DBE. a. Nondiscrimination Statement
The contractor, subrecipient or subcontractor will never exclude any person from participation in, deny any person the benefits of, or otherwise discriminate against anyone in connection with the award and performance of any contract covered by 49 CFR 26 on the basis of race, color, sex, or national origin. In administering the Local Agency components of the DBE Program Plan, the contractor, subrecipient or subcontractor will not, directly, or through contractual or other arrangements, use criteria or methods of administration that have the effect of defeating or substantially impairing accomplishment of the objectives of the DBE Program Plan with respect to individuals of a particular race, color, sex, or national origin.
January 2021
EXHIBIT E
https://dot.ca.gov/programs/civil-rights/dbe-search
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
b. Contract Assurance
Under 49 CFR 26.13(b):
The contractor, subrecipient or subcontractor shall not discriminate on the basis of race, color, national origin, or sex in the performance of this contract. The contractor shall carry out applicable requirements of 49 CFR 26 in the award and administration of federal-aid contracts. Failure by the contractor to carry out these requirements is a material breach of this contract, which may result in the termination of this contract or such other remedy as the recipient deems appropriate, which may include, but is not limited to:
(1) Withholding monthly progress payments;
(2) Assessing sanctions;
(3) Liquidated damages; and/or
(4) Disqualifying the contractor from future bidding as non-responsible. c. Prompt Progress Payment
The prime contractor or subcontractor shall pay to any subcontractor, not later than seven days after receipt of each progress payment, unless otherwise agreed to in writing, the respective amounts allowed the contractor on account of the work performed by the subcontractors, to the extent of each subcontractor’s interest therein. In the event that there is a good faith dispute over all or any portion of the amount due on a progress payment from the prime contractor or subcontractor to a subcontractor, the prime contractor or subcontractor may withhold no more than 150 percent of the disputed amount. Any violation of this requirement shall constitute a cause for disciplinary action and shall subject the licensee to a penalty, payable to the subcontractor, of 2 percent of the amount due per month for every month that payment is not made.
In any action for the collection of funds wrongfully withheld, the prevailing party shall be entitled to his or her attorney’s fees and costs. The sanctions authorized under this requirement shall be separate from, and in addition to, all other remedies, either civil, administrative, or criminal. This clause applies to both DBE and non-DBE subcontractors.
d. Prompt Payment of Withheld Funds to Subcontractors
The Agency may hold retainage from the prime contractor and shall make prompt and regular incremental acceptances of portions, as determined by the Agency, of the contract work, and pay retainage to the prime contractor based on these acceptances. The Agency shall designate one of the methods below in the contract to ensure prompt and full payment of any retainage kept by the prime contractor or subcontractor to a subcontractor. The Agency shall include either Method 1, Method 2, or Method 3 below and delete the other two.
Method 1: No retainage will be held by the Agency from progress payments due to the prime contractor.
Prime contractors and subcontractors are prohibited from holding retainage from subcontractors. Any delay or postponement of payment may take place only for good cause and with the Agency’s prior written approval. Any violation of these provisions shall subject the violating contractor or subcontractor to the penalties, sanctions, and other remedies specified in Section 7108.5 of the California Business and Professions Code and Section 10262 of the California Public Contract Code. This requirement shall not be construed to limit or impair any contractual, administrative or judicial remedies, otherwise available to the contractor or subcontractor in the event of a dispute involving late payment or nonpayment by the contractor, deficient subcontractor performance and/or noncompliance by a subcontractor. This clause applies to both DBE and non-DBE subcontractors.
Method 2: No retainage will be held by the Agency from progress payments due to the prime contractor.
Any retainage kept by the prime contractor or by a subcontractor must be paid in full to the earning subcontractor within seven (7) days after the subcontractor’s work is satisfactorily completed. Any delay or postponement of payment may take place only for good cause and with the Agency’s prior written approval. Any violation of these provisions shall subject the violating contractor or subcontractor to the penalties, sanctions, and remedies specified in Section 7108.5 of the California Business and Professions Code and Section 10262 of the California Public Contract Code. This requirement shall not be construed to limit or impair any contractual, administrative or judicial remedies, otherwise available to the contractor or subcontractor in the event of a dispute involving late payment or nonpayment by the contractor, deficient subcontractor performance and/or noncompliance by a subcontractor. This clause applies to both DBE and non-DBE subcontractors.
January 2021
EXHIBIT E Page 106 of 130 EXHIBIT 2 950
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
Method 3: The Agency shall hold retainage from the prime contractor and shall make prompt and regular incremental acceptances of portions, as determined by the Agency of the contract work and pay retainage to the prime contractor based on these acceptances. The prime contractor or subcontractor shall return all monies withheld in retention from all subcontractors within seven (7) days after receiving payment for work satisfactorily completed and accepted including incremental acceptances of portions of the contract work by the Agency. Any delay or postponement of payment may take place only for good cause and with the Agency’s prior written approval. Any violation of these provisions shall subject the violating prime contractor or subcontractor to the penalties, sanctions, and other remedies specified in Section 7108.5 of the California Business and Professions Code and Section 10262 of the California Public Contract Code. This requirement shall not be construed to limit or impair any contractual, administrative or judicial remedies otherwise available to the contractor or subcontractor in the event of a dispute involving late payment or nonpayment by the contractor; deficient subcontractor performance and/or noncompliance by a subcontractor. This clause applies to both DBE and non-DBE subcontractors.
Any violation of these provisions shall subject the violating prime contractor or subcontractor to the penalties, sanctions and other remedies specified therein. These requirements shall not be construed to limit or impair any contractual, administrative, or judicial remedies otherwise available to the prime contractor or subcontractor in the event of a dispute involving late payment or nonpayment by the prime contractor, deficient subcontract performance, or noncompliance by a subcontractor. e. Termination and Substitution of DBE Subcontractors
The prime contractor shall utilize the specific DBEs listed to perform the work and supply the materials for which each is listed unless the contractor obtains the Agency’s written consent. The prime contractor shall not terminate or substitute a listed DBE for convenience and perform the work with their own forces or obtain materials from other sources without prior written authorization from the Agency. Unless the Agency’s prior written consent is provided, the contractor shall not be entitled to any payment for work or material unless it is performed or supplied by the listed DBE on the Exhibit 15-G Construction Contract DBE Commitment form, included in the Bid.
The Agency authorizes a request to use other forces or sources of materials if the bidder shows any of the following justifications:
1. Listed DBE fails or refuses to execute a written contract based on plans and specifications for the project.
2. The Local Agency stipulated that a bond is a condition of executing the subcontract and the listed DBE fails to meet the Local Agency’s bond requirements.
3. Work requires a contractor's license and listed DBE does not have a valid license under Contractors License Law.
4. Listed DBE fails or refuses to perform the work or furnish the listed materials (failing or refusing to perform is not an allowable reason to remove a DBE if the failure or refusal is a result of bad faith or discrimination).
5. Listed DBE's work is unsatisfactory and not in compliance with the contract.
6. Listed DBE is ineligible to work on the project because of suspension or debarment.
7. Listed DBE becomes bankrupt or insolvent.
8. Listed DBE voluntarily withdraws with written notice from the Contract
9. Listed DBE is ineligible to receive credit for the type of work required.
10. Listed DBE owner dies or becomes disabled resulting in the inability to perform the work on the Contract.
11. The Agency determines other documented good cause.
The prime contractor shall notify the original DBE of the intent to use other forces or material sources and provide the reasons, allowing the DBE 5 days to respond to the notice and advise the prime contractor and the Agency of the reasons why the use of other forces or sources of materials should not occur.
January 2021
EXHIBIT E Page 107 of 130 EXHIBIT 2 951
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
The prime contractor’s request to use other forces or material sources must include:
1. One or more of the reasons listed in the preceding paragraph.
2. Notices from the prime contractor to the DBE regarding the request.
3. Notices from the DBEs to the prime contractor regarding the request.
If a listed DBE is terminated or substituted, the prime contractor must make good faith efforts to find another DBE to substitute for the original DBE. The substitute DBE must perform at least the same amount of work as the original DBE under the contract to the extent needed to meet or exceed the DBE goal. f. Commitment and Utilization
Note: In the Agency’s reports of DBE participation to Caltrans, the Agency must display both commitments and attainments.
The Agency’s DBE program must include a monitoring and enforcement mechanism to ensure that DBE commitments reconcile to DBE utilization.
The bidder shall submit the Exhibit 15-G Construction Contract DBE Commitment, included in the Bid book.
This exhibit is the bidder’s DBE commitment form. If the form is not submitted with the bid, the bidder must remove the form from the Bid book before submitting their bid.
The bidder shall complete and sign Exhibit 15-G Construction Contract DBE Commitment included in the contract documents regardless of whether DBE participation is reported. The bidder shall provide written confirmation from each DBE that the DBE is participating in the Contract. A copy of a DBE's quote serves as written confirmation. If a DBE is participating as a joint venture partner, the bidder shall submit a copy of the joint venture agreement.
If the DBE Commitment form, Exhibit 15-G, is not submitted with the bid, it must be completed and submitted by all bidders to the Agency within five (5) days of bid opening. If the bidder does not submit the DBE Commitment form within the specified time, the Agency will find the bidder’s bid nonresponsive.
The prime contractor shall use each DBE subcontractor as listed on Exhibit 12-B Bidder’s List of Subcontractors (DBE and Non-DBE), and Exhibit 15-G Construction Contract DBE Commitment form unless they receive authorization for a substitution.
The Agency shall request the prime contractor to:
1. Notify the Resident Engineer or Inspector of any changes to its anticipated DBE participation
2. Provide this notification before starting the affected work
3. Maintain records including:
• Name and business address of each 1st-tier subcontractor • Name and business address of each DBE subcontractor, DBE vendor, and DBEtrucking company, regardless of tier
• Date of payment and total amount paid to each business (see Exhibit 9-F Monthly Disadvantaged Business Enterprise Payment)
If the prime contractor is a DBE contractor, they shall include the date of work performed by their own forces and the corresponding value of the work.
Before the 15th of each month, the prime contractor shall submit a Monthly DBE Trucking Verification (LAPM Exhibit 16-Z1) form.
If a DBE is decertified before completing its work, the DBE must notify the prime contractor in writing of the decertification date. If a business becomes a certified DBE before completing its work, the business must notify the prime contractor in writing of the certification date. The prime contractor shall submit the notifications. Upon work completion, the prime contractor shall complete a Disadvantaged Business Enterprises (DBE) Certification Status Change, Exhibit 17-O, form and submit the form within 30 days of contract acceptance.
January 2021
EXHIBIT E Page 108 of 130 EXHIBIT 2 952
I
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
Upon work completion, the prime contractor shall complete Exhibit 17-F Final Report – Utilization of Disadvantaged Business Enterprises (DBE), First-Tier Subcontractors and submit it within 90 days of contract acceptance. The Agency will withhold $10,000 until the form is submitted. The Agency releases the withhold upon submission of the completed form.
g. DBE RUNNING TALLY OF ATTAINMENTS
After submitting an invoice for reimbursement that includes a payment to a DBE, but no later than the 10th of the following month, the prime contractor/consultant shall complete and email the Exhibit 9- F: Disadvantaged Business Enterprise Running Tally of Payments to [email protected] with a copy to the Agency.
2. BID OPENINGThe Agency publicly opens and reads bids at the time and place shown on the Notice to Contractors.
3. BID RIGGING The U.S. Department of Transportation (DOT) provides a toll-free hotline to report bid rigging activities. Use the hotline to report bid rigging, bidder collusion, and other fraudulent activities. The hotline number is (800) 424-9071. The service is available 24 hours 7 days a week and is confidential and anonymous. The hotline is part of the DOT's effort to identify and investigate highway construction contract fraud and abuse and is operated under the direction of the DOT Inspector General.
4. CONTRACT AWARD If the Agency awards the contract, the award is made to the lowest responsible and responsive bidder.
5. CONTRACTOR LICENSE
The Contractor must be properly licensed as a contractor from contract award through Contract acceptance (Public Contract Code § 10164).
6. CHANGED CONDITIONS
a. Differing Site Conditions
1. During the progress of the work, if subsurface or latent physical conditions are encountered at the site differing materially from those indicated in the contract or if unknown physical conditions of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent in the work provided for in the contract, are encountered at the site, the party discovering such conditions shall promptly notify the other party in writing of the specific differing conditions before the site is disturbed and before the affected work is performed.
2. Upon written notification, the engineer will investigate the conditions, and if it is determined that the conditions materially differ and cause an increase or decrease in the cost or time required for the performance of any work under the contract, an adjustment, excluding anticipated profits, will be made and the contract modified in writing accordingly. The engineer will notify the contractor of the determination whether or not an adjustment of the contract is warranted.
3. No contract adjustment which results in a benefit to the contractor will be allowed unless the contractor has provided the required written notice.
4. No contract adjustment will be allowed under this clause for any effects caused on unchanged work. (This provision may be omitted by the Local Agency, at their option.) b. Suspensions of Work Ordered by the Engineer
1. If the performance of all or any portion of the work is suspended or delayed by the engineer in writing for an unreasonable period of time (not originally anticipated, customary, or inherent to the construction industry) and the contractor believes that additional compensation and/or contract time is due as a result of such suspension or delay, the contractor shall submit to the engineer in writing a request for adjustment within 7 calendar days of receipt of the notice to resume work. The request shall set forth the reasons and support for such adjustment.
2. Upon receipt, the engineer will evaluate the contractor's request. If the engineer agrees that the cost and/or time required for the performance of the contract has increased as a result of such suspension and the suspension was caused by conditions beyond the control of and not the fault of the contractor, its suppliers, or subcontractors at any approved tier, and not caused by weather, the engineer will make an adjustment (excluding profit) and modify the contract in
January 2021
EXHIBIT E Page 109 of 130 EXHIBIT 2 953
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
writing accordingly. The contractor will be notified of the engineer's determination whether or not an adjustment of the contract is warranted.
3. No contract adjustment will be allowed unless the contractor has submitted the request for adjustment within the time prescribed.
4. No contract adjustment will be allowed under this clause to the extent that performance would have been suspended or delayed by any other cause, or for which an adjustment is provided or excluded under any other term or condition of this contract. c. Significant Changes in the Character of Work
1. The engineer reserves the right to make, in writing, at any time during the work, such changes in quantities and such alterations in the work as are necessary to satisfactorily complete the project.
Such changes in quantities and alterations shall not invalidate the contract nor release the surety, and the contractor agrees to perform the work as altered.
2. If the alterations or changes in quantities significantly change the character of the work under the contract, whether such alterations or changes are in themselves significant changes to the character of the work or by affecting other work cause such other work to become significantly different in character, an adjustment, excluding anticipated profit, will be made to the contract.
The basis for the adjustment shall be agreed upon prior to the performance of the work. If a basis cannot be agreed upon, then an adjustment will be made either for or against the contractor in such amount as the engineer may determine to be fair andequitable.
3. If the alterations or changes in quantities do not significantly change the character of the work to be performed under the contract, the altered work will be paid for as provided elsewhere in the contract.
4. The term “significant change” shall be construed to apply only to the following circumstances:
• When the character of the work as altered differs materially in kind or nature from that involved or included in the original proposed construction; or • When a major item of work, as defined elsewhere in the contract, is increased in excess of 125 percent or decreased below 75 percent of the original contract quantity. Any allowance for an increase in quantity shall apply only to that portion in excess of 125 percent of original contract item quantity, or in case of a decrease below 75 percent, to the actual amount of work performed.
7. BEGINNING OF WORK, TIME OF COMPLETION AND LIQUIDATED DAMAGES The Contractor shall begin work within 15 calendar days after the issuance of the Notice to Proceed.
This work shall be diligently prosecuted to completion before the expiration of WORKING DAYS beginning on the fifteenth calendar day after the date shown on the Notice to Proceed.
The Contractor shall pay to the City/County the sum of $ per day, for each and every calendar days’ delay in finishing the work in excess of the number of working days prescribed above.
8. BUY AMERICA
Furnish steel and iron materials to be incorporated into the work with certificates of compliance and certified mill test reports. Mill test reports must indicate where the steel and iron were melted and manufactured. Steel and iron materials must be produced in the U.S. except:
1. Foreign pig iron and processed, pelletized, and reduced iron ore may be used in the domestic production of the steel and iron materials [60 Fed Reg 15478 (03/24/1995)];
2. If the total combined cost of the materials does not exceed the greater of 0.1 percent of the total bid or $2,500, materials produced outside the U.S. may be used.
Production includes:
January 2021
EXHIBIT E Page 110 of 130 EXHIBIT 2 954
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
1. Processing steel and iron materials, including smelting or other processes that alter the physical form or shape (such as rolling, extruding, machining, bending, grinding, and drilling) or chemical composition;
2. Coating application, including epoxy coating, galvanizing, and painting, that protects or enhances the value of steel and iron materials.
9. QUALITY ASSURANCE
The Local Agency uses a Quality Assurance Program (QAP) to ensure a material is produced to comply with the Contract. The Local Agency may examine the records and reports of tests the prime contractor performs if they are available at the job site. Schedule work to allow time for QAP.
10. PROMPT PAYMENT FROM THE AGENCY TO THE CONTRACTORS
The Agency shall make any progress payment within 30 days after receipt of an undisputed and properly submitted payment request from a contractor on a construction contract. If the Agency fails to pay promptly, the Agency shall pay interest to the contractor, which accrues at the rate of 10 percent per annum on the principal amount of a money judgment remaining unsatisfied. Upon receipt of a payment request, the Agency shall act in accordance with both of the following:
1. Each payment request shall be reviewed by the Agency as soon as practicable after receipt for the purpose of determining that it is a proper payment request.
2. Any payment request determined not to be a proper payment request suitable for payment shall be returned to the contractor as soon as practicable, but not later than seven (7) days, after receipt. A request returned pursuant to this paragraph shall be accompanied by a document setting forth in writing the reasons why the payment request is not proper.
11. FORM FHWA-1273 REQUIRED CONTRACT PROVISIONS FEDERAL-AID CONTRACTS (Excluding ATTACHMENT A - EMPLOYMENT AND MATERIALS PREFERENCE FOR APPALACHIAN
DEVELOPMENT HIGHWAY SYSTEM OR APPALACHIAN LOCAL ACCESS ROAD CONTRACTS) [The following 12 pages must be physically inserted into the contract without modification.]
January 2021
EXHIBIT E Page 111 of 130 EXHIBIT 2 955
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
FHWA-1273 -- Revised May 1, 2012
REQUIRED CONTRACT
PROVISIONS FEDERAL-AID
CONSTRUCTION CONTRACTS
January 2021
EXHIBIT E Page 112 of 130 EXHIBIT 2 956
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
I. General
II. Nondiscrimination
III. No segregated Facilities
IV. Davis-Bacon and Related Act Provisions
V. Contract Work Hours and Safety Standards Act Provisions VI. Subletting or Assigning the Contract
VII. Safety: Accident Prevention
VIII. False Statements Concerning Highway Projects
IX. Implementation of Clean Air Act and Federal Water Pollution Control Act
X. Compliance with Government wide Suspension and Debarment Requirements
XI. Certification Regarding Use of Contract Funds for Lobbying
ATTACHMENTS
A. Employment and Materials Preference for Appalachian Development Highway System or Appalachian Local Access Road Contracts (included in Appalachian contracts only)
I. GENERAL
1. Form FHWA-1273 must be physically incorporated in each construction contract funded under Title 23 (excluding emergency contracts solely intended for debris removal). The contractor (or subcontractor) must insert this form in each subcontract and further require its inclusion in all lower tier subcontracts (excluding purchase orders, rental agreements and other agreements for supplies or services).
The applicable requirements of Form FHWA-1273 are incorporated by reference for work done under any purchase order, rental agreement or agreement for other services. The prime contractor shall be responsible for compliance by any subcontractor, lower-tier subcontractor or service provider.
Form FHWA-1273 must be included in all Federal-aid design-build contracts, in all subcontracts and in lower tier subcontracts (excluding subcontracts for design services, purchase orders, rental agreements and other agreements for supplies or services). The design-builder shall be responsible for compliance by any subcontractor, lower-tier subcontractor or service provider.
Contracting agencies may reference Form FHWA-1273 in bid proposal or request for proposal documents, however, the Form FHWA-1273 must be physically incorporated (not referenced) in all contracts, subcontracts and lower-tier subcontracts (excluding purchase orders, rental agreements and other agreements for supplies or services related to a construction contract).
2. Subject to the applicability criteria noted in the following sections, these contract provisions shall apply to all work performed on the contract by the contractor's own organization and with the assistance of workers under the contractor's immediate superintendence and to all work performed on the contract by piecework, station work, or by subcontract.
3. A breach of any of the stipulations contained in these Required Contract Provisions may be sufficient grounds for withholding of progress payments, withholding of final payment, termination of the contract, suspension / debarment or any other action determined to be appropriate by the contracting agency and FHWA.
4. Selection of Labor: During the performance of this contract, the contractor shall not use convict labor for any purpose within the limits of a construction project on a Federal-aid highway unless it is labor performed by convicts who are on parole, supervised release, or probation. The term Federal-aid highway does not include roadways functionally classified as local roads or rural minor collectors.
II. NONDISCRIMINATION
The provisions of this section related to 23 CFR Part 230 are applicable to all Federal-aid construction contracts and to all related construction subcontracts of $10,000 or more. The provisions of 23 CFR Part 230 are not applicable to material supply, engineering, or architectural service contracts.
In addition, the contractor and all subcontractors must comply with the following policies: Executive Order 11246, 41 CFR 60, 29 CFR 1625- 1627, Title 23 USC Section 140, the Rehabilitation Act of 1973, as amended (29 USC 794), Title VI of the Civil Rights Act of 1964, as amended, and related regulations including 49 CFR Parts 21, 26 and 27; and 23 CFR Parts 200, 230, and 633.
The contractor and all subcontractors must comply with: the requirements of the Equal Opportunity Clause in 41 CFR 60-1.4(b) and, for all construction contracts exceeding $10,000, the Standard Federal Equal Employment Opportunity Construction Contract Specifications in 41 CFR 60-4.3.
Note: The U.S. Department of Labor has exclusive authority to determine compliance with Executive Order 11246 and the policies of the Secretary of Labor including 41 CFR 60, and 29 CFR 1625-1627.
The contracting agency and the FHWA have the authority and the responsibility to ensure compliance with Title 23 USC Section 140, the Rehabilitation Act of 1973, as amended (29 USC 794), and Title VI of the Civil Rights Act of 1964, as amended, and related regulations including 49 CFR Parts 21, 26 and 27; and 23 CFR Parts 200, 230, and 633.
The following provision is adopted from 23 CFR 230, Appendix A, with appropriate revisions to conform to the U.S. Department of Labor (US DOL) and FHWA requirements.
1. Equal Employment Opportunity: Equal employment opportunity (EEO) requirements not to discriminate and to take affirmative action to assure equal opportunity as set forth under laws, executive orders, rules, regulations (28 CFR 35, 29 CFR 1630, 29 CFR 1625-1627, 41 CFR 60 and 49 CFR 27) and orders of the Secretary of Labor as modified by the provisions prescribed herein, and imposed pursuant to 23 U.S.C. 140 shall constitute the EEO and specific affirmative action standards for the contractor's project activities under this contract. The provisions of the Americans with Disabilities Act of 1990 (42 U.S.C. 12101 et seq.) set forth under 28 CFR 35 and 29 CFR 1630 are incorporated by reference in this contract. In the execution of this contract, the contractor agrees to comply with the following minimum specific requirement activities of EEO:
a. The contractor will work with the contracting agency and the Federal Government to ensure that it has made every good faith effort to provide equal opportunity with respect to all of its terms and conditions of employment and in their review of activities under the contract.
b. The contractor will accept as its operating policy thefollowing statement:
"It is the policy of this Company to assure that applicants are employed, and that employees are treated during employment, without regard to their race, religion, sex, color, national origin, age or disability. Such action shall include: employment, upgrading, demotion, or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship, pre-apprenticeship, and/or on-the-job training." FHWA-1273 -- Revised May 1, 2012
January 2021
EXHIBIT E Page 113 of 130 EXHIBIT 2 957
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
2. EEO Officer: The contractor will designate and make known to the contracting officers and EEO Officer who will have the responsibility for and must be capable of effectively administering and promoting and active EEO program and who must be assigned adequate authority and responsibility to do so.
3. Dissemination of Policy: All members of the contractor's staff who are authorized to hire, supervise, promote, and discharge employees, or who recommend such action, or who are
substantially involved in such action, will be made fully cognizant of, and will implement, the contractor's EEO policy and contractual responsibilities to provide EEO in each grade and classification of employment. To ensure that the above agreement will be met, the following actions will be taken as a minimum:
a. Periodic meetings of supervisory and personnel office employees will be conducted before the start of work and then not less often than once every six months, at which time the contractor's EEO policy and its implementation will bereviewed and explained. The meetings will be conducted by the EEO Officer.
b. All new supervisory or personnel office employees will be given a thorough indoctrination by the EEO Officer, covering all major aspects of the contractor's EEO obligations within thirty days following their reporting for duty with the contractor. c. All personnel who are engaged in direct recruitment for the project will be instructed by the EEO Officer in the contractor's procedures for locating and hiring minorities and women. d. Notices and posters setting forth the contractor's EEO policywill be placed in areas readily accessible to employees, applicants for employment and potential employees.
e. The contractor's EEO policy and the procedures to implement such policy will be brought to the attention of employees by means of meetings, employee handbooks, or other appropriate means.
4. Recruitment: When advertising for employees, the contractor will include in all advertisements for employees the notation: "An Equal Opportunity Employer." All such advertisements will be placed in publications having a large circulation among minorities and women in the area from which the project work force would normally be derived.
a. The contractor will, unless precluded by a valid bargaining agreement, conduct systematic and direct recruitment through public and private employee referral sources likely to yield qualified minorities and women. To meet this requirement, the contractor will identify sources of potential minority group employees, and establish with such identified sources
procedures whereby minority and women applicants may be referred to the contractor for employment consideration. b. In the event the contractor has a valid bargaining agreement providing for exclusive hiring hall referrals, the contractor is expected to observe the provisions of that agreement to the extent that the system meets the contractor's compliance with EEO contract provisions. Where implementation of such an agreement has the effect of discriminating against minorities or women, or obligates the contractor to do the same, such implementation violates Federal nondiscrimination provisions. c. The contractor will encourage its present employees to refer minorities and women as applicants for employment.
Information and procedures with regard to referring such applicants will be discussed with employees.
5. Personnel Actions: Wages, working conditions, and employee benefits shall be established and administered, and personnel actions of every type, including hiring, upgrading, promotion, transfer, demotion, layoff, and termination, shall be taken without regard to race, color, religion, sex, national origin, age or disability.
The following procedures shall be followed:
a. The contractor will conduct periodic inspections of project sites to insure that working conditions and employee facilities do not indicate discriminatory treatment of project site personnel. b. The contractor will periodically evaluate the spread of wagespaid within each classification to determine any evidence of discriminatory wage practices.
c. The contractor will periodically review selected personnel actions in depth to determine whether there is evidence ofdiscrimination.
Where evidence is found, the contractor will promptly take corrective action. If the review indicates that the discrimination may extend beyond the actions reviewed, such corrective action shall include all affected persons.
d. The contractor will promptly investigate all complaints of alleged discrimination made to the contractor in connection with its obligations under this contract, will attempt to resolve such complaints, and will take appropriate corrective action within a reasonable time. If the investigation indicates that the discrimination may affect persons other than the complainant, such corrective action shall include such other persons. Upon completion of each investigation, the contractor will inform every complainant of all of their avenues of appeal.
6. Training and Promotion:
a. The contractor will assist in locating, qualifying, and increasing the skills of minorities and women who are applicants for employment or current employees. Such efforts should be aimed at developing full journey level status employees in the type of trade or job classification involved.
b. Consistent with the contractor's work force requirements and as permissible under Federal and State regulations, the contractor shall make full use of training programs, i.e., apprenticeship, and on-the-job training programs for the geographical area of contract performance. In the event a special provision for training is provided under this contract, this subparagraph will be superseded as indicated in the special provision. The contracting agency may reserve training positions for persons who receive welfare assistance in accordance with 23 U.S.C. 140(a). c. The contractor will advise employees and applicants for employment of available training programs and entrance
requirements for each.
d. The contractor will periodically review the training andpromotion potential of employees who are minorities and women and will encourage eligible employees to apply for such training and promotion.
January 2021
EXHIBIT E Page 114 of 130 EXHIBIT 2 958
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
7. Unions: If the contractor relies in whole or in part upon unions as a source of employees, the contractor will use good faith efforts to obtain the cooperation of such unions to increase opportunities for minorities and women. Actions by the contractor, either directly or through a contractor's association acting as agent, will include the procedures set forth below:
a. The contractor will use good faith efforts to develop, in cooperation with the unions, joint training programs aimed toward qualifying more minorities and women for membership in the unions and increasing the skills of minorities and women so that they may qualify for higher paying employment.
b. The contractor will use good faith efforts to incorporate an EEO clause into each union agreement to the end that such union will be contractually bound to refer applicants without regard to their race, color, religion, sex, national origin, age or disability. c. The contractor is to obtain information as to the referral practices and policies of the labor union except that to the extent such information is within the exclusive possession of the labor union and such labor union refuses to furnish such information to the contractor, the contractor shall so certify to the contracting agency and shall set forth what efforts have been made to obtain such information.
d. In the event the union is unable to provide the contractor with a reasonable flow of referrals within the time limit set forth in the collective bargaining agreement, the contractor will, through independent recruitment efforts, fill the employment vacancies without regard to race, color, religion, sex, national origin, age or disability; making full efforts to obtain qualified and/or qualifiable minorities and women. The failure of a union to provide sufficient referrals (even though it is obligated to provide exclusive referrals under the terms of a collective bargaining agreement) does not relieve the contractor from the requirements of this paragraph. In the event the union referral practice prevents the contractor from meeting the obligations pursuant to Executive Order 11246, as amended, and these special provisions, such contractor shall immediately notify the contracting agency.
8. Reasonable Accommodation for Applicants / Employees
with Disabilities: The contractor must be familiar with the requirements for and comply with the Americans with Disabilities Act and all rules and regulations established there under.
Employers must provide reasonable accommodation in all
employment activities unless to do so would cause an undue hardship.
9. Selection of Subcontractors, Procurement of Materials and Leasing of Equipment: The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
FHWA-1273 -- Revised May 1, 2012
10. Assurance Required by 49 CFR 26.13(b):
a. The requirements of 49 CFR Part 26 and the State DOT’s U.S.
DOT-approved DBE program are incorporated by reference. b. The contractor or subcontractor shall not discriminate on the basis of race, color, national origin, or sex in the performance of this contract. The contractor shall carry out applicable requirements of 49 CFR Part 26 in the award and administration of DOT-assisted contracts. Failure by the contractor to carry out these requirements is a material breach of this contract, which may result in the termination of this contract or such other remedy as the contracting agency deems appropriate.
11. Records and Reports: The contractor shall keep such records as necessary to document compliance with the EEO requirements.
Such records shall be retained for a period of three years following the date of the final payment to the contractor for all contract work and shall be available at reasonable times and places for inspection by authorized representatives of the contracting agency and the FHWA.
a. The records kept by the contractor shall document the following:
(1) The number and work hours of minority and non-minority group members and women employed in each work classification on the project;
(2) The progress and efforts being made in cooperation with unions, when applicable, to increase employment opportunities for minorities and women; and
(3) The progress and efforts being made in locating, hiring, training, qualifying, and upgrading minorities and women.
b. The contractors and subcontractors will submit an annual report to the contracting agency each July for the duration of the project, indicating the number of minority, women, and nonminority group employees currently engaged in each work classification required by the contract work. This information is to be reported on Form FHWA-1391. The staffing data should represent the project work force on board in all or any part of the last payroll period preceding the end of July. If on-the-job training is being required by special provision, the contractor will be required to collect and report training data. The employment data should reflect the work force on board during all or any part of the last payroll period preceding the end of July.
III. NONSEGREGATED FACILITIES
This provision is applicable to all Federal-aid construction contracts and to all related construction subcontracts of $10,000 or more.
The contractor must ensure that facilities provided for employees are provided in such a manner that segregation on the basis of race, color, religion, sex, or national origin cannot result. The contractor may neither require such segregated use by written or oral policies nor tolerate such use by employee custom. The contractor's obligation extends further to ensure that its employees are not assigned to perform their services at any location, under the contractor's control, where the facilities are segregated. The term "facilities" includes waiting rooms, work areas, restaurants and other eating areas, time clocks, restrooms, washrooms, locker rooms, and other storage or dressing areas, parking lots, drinking fountains, recreation or entertainment areas, transportation, and housing provided for employees. The contractor shall provide separate or single-user restrooms and necessary dressing or sleeping areas to assure privacy between sexes.
January 2021
EXHIBIT E Page 115 of 130 EXHIBIT 2 959
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
IV. DAVIS-BACON AND RELATED ACT PROVISIONS
This section is applicable to all Federal-aid construction projects exceeding $2,000 and to all related subcontracts and lower-tier subcontracts (regardless of subcontract size). The requirements apply to all projects located within the right-of-way of a roadway that is functionally classified as Federal-aid highway. This excludes roadways functionally classified as local roads or rural minor collectors, which are exempt. Contracting agencies may elect to apply these requirements to other projects.
The following provisions are from the U.S. Department of Labor regulations in 29 CFR 5.5 “Contract provisions and related matters” with minor revisions to conform to the FHWA-1273 format and FHWA program requirements.
1. Minimum wages
a. All laborers and mechanics employed or working upon the site of the work, will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by regulations issued by the Secretary of Labor under the Copeland Act (29 CFR part 3)), the full amount of wages and bona fide fringe benefits (or cash equivalents thereof) due at time of payment computed at rates not less than those contained in the wage determination of the Secretary of Labor which is attached hereto and made a part hereof, regardless of any contractual relationship which may be alleged to exist between the contractor and such laborers and mechanics.
Contributions made or costs reasonably anticipated for bona fide fringe benefits under section 1(b)(2) of the Davis-Bacon Act on behalf of laborers or mechanics are considered wages paid to such laborers or mechanics, subject to the provisions of paragraph 1.d. of this section; also, regular contributions made or costs incurred for more than a weekly period (but not less often than quarterly) under plans, funds, or programs which cover the particular weekly period, are deemed to be constructively made or incurred during such weekly period. Such laborers and mechanics shall be paid the appropriate wage rate and fringe benefits on the wage
determination for the classification of work actually performed, without regard to skill, except as provided in 29 CFR 5.5(a)(4).
Laborers or mechanics performing work in more than one
classification may be compensated at the rate specified for each classification for the time actually worked therein: Provided, That the employer's payroll records accurately set forth the time spent in each classification in which work is performed. The wage determination (including any additional classification and wage rates conformed under paragraph 1.b. of this section) and the Davis-Bacon poster (WH–1321) shall be posted at all times by the contractor and its subcontractors at the site of the work in a prominent and accessible place where it can be easily seen by the workers.
b. (1) The contracting officer shall require that any class of laborers or mechanics, including helpers, which is not listed in the wage determination and which is to be employed under the contract shall be classified in conformance with the wage determination. The contracting officer shall approve an additional classification and wage rate and fringe benefits therefore only when the following criteria have been met:
FHWA-1273 -- Revised May 1, 2012
(i) The work to be performed by the classification requested is not performed by a classification in the wage determination; and (ii) The classification is utilized in the area by the construction industry; and
(iii) The proposed wage rate, including any bona fide fringe benefits, bears a reasonable relationship to the wage rates contained in the wage determination.
(2) If the contractor and the laborers and mechanics to be employed in the classification (if known), or their
representatives, and the contracting officer agree on the classification and wage rate (including the amount designated for fringe benefits where appropriate), a report of the action taken shall be sent by the contracting officer to the Administrator of the Wage and Hour Division, Employment Standards
Administration, U.S. Department of Labor, Washington, DC 20210. The Administrator, or an authorized representative, will approve, modify, or disapprove every additional classification action within 30 days of receipt and so advise the contracting officer or will notify the contracting officer within the 30-day period that additional time is necessary.
(3) In the event the contractor, the laborers or mechanics to be employed in the classification or their representatives, and the contracting officer do not agree on the proposed classification and wage rate (including the amount designated for fringe benefits, where appropriate), the contracting officer shall refer the questions, including the views of all interested parties and the recommendation of the contracting officer, to the Wage and Hour Administrator for determination. The Wage and Hour Administrator, or an authorized representative, will issue a determination within 30 days of receipt and so advise the contracting officer or will notify the contracting officer within the 30-day period that additional time is necessary.
(4) The wage rate (including fringe benefits where appropriate) determined pursuant to paragraphs 1.b.(2) or 1.b.(3) of this section, shall be paid to all workers performing work in the classification under this contract from the first day on which work is performed in the classification.
c. Whenever the minimum wage rate prescribed in the contract for a class of laborers or mechanics includes a fringe benefit which is not expressed as an hourly rate, the contractor shall either pay the benefit as stated in the wage determination or shall pay another bona fide fringe benefit or an hourly cash equivalent thereof.
d. If the contractor does not make payments to a trustee or other third person, the contractor may consider as part of the wages of any laborer or mechanic the amount of any costs reasonably anticipated in providing bona fide fringe benefits under a plan or program, Provided, That the Secretary of Labor has found, upon the written request of the contractor, that the applicable standards of the Davis-Bacon Act have been met. The Secretary of Labor may require the contractor to set aside in a separate account assets for the meeting of obligations under the plan or program.
January 2021
EXHIBIT E Page 116 of 130 EXHIBIT 2 960
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
2. Withholding
The contracting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor, withhold or cause to be withheld from the contractor under this contract, or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to DavisBacon prevailing wage requirements, which is held by the same prime contractor, so much of the accrued payments or advances as may be considered necessary to pay laborers and mechanics, including apprentices, trainees, and helpers, employed by the contractor or any subcontractor the full amount of wages required by the contract. In the event of failure to pay any laborer or mechanic, including any apprentice, trainee, or helper, employed or working on the site of the work, all or part of the wages required by the contract, the contracting agency may, after written notice to the contractor, take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds until such violations have ceased.
3. Payrolls and basic records
a. Payrolls and basic records relating thereto shall be maintained by the contractor during the course of the work and preserved for a period of three years thereafter for all laborers and mechanics working at the site of the work. Such records shall contain the name, address, and social security number of each such worker, his or her correct classification, hourly rates of wages paid (including rates of contributions or costs anticipated for bona fide fringe benefits or cash equivalents thereof of the types described in section 1(b)(2)(B) of the Davis-Bacon Act), daily and weekly number of hours worked, deductions made and actual wages paid.
Whenever the Secretary of Labor has found under 29 CFR
5.5(a)(1)(iv) that the wages of any laborer or mechanic include the amount of any costs reasonably anticipated in providing benefits under a plan or program described in section 1(b)(2)(B) of the Davis-Bacon Act, the contractor shall maintain records which show that the commitment to provide such benefits is enforceable, that the plan or program is financially responsible, and that the plan or program has been communicated in writing to the laborers or mechanics affected, and records which show the costs anticipated or the actual cost incurred in providing such benefits. Contractors employing apprentices or trainees under approved programs shall maintain written evidence of the registration of apprenticeship programs and certification of trainee programs, the registration of the apprentices and trainees, and the ratios and wage rates prescribed in the applicable programs.
b. (1) The contractor shall submit weekly for each week in which any contract work is performed a copy of all payrolls to the contracting agency. The payrolls submitted shall set out accurately and completely all of the information required to be maintained under 29 CFR 5.5(a)(3)(i), except that full social security numbers and home addresses shall not be included on weekly transmittals.
Instead the payrolls shall only need to include an individually identifying number for each employee ( e.g. , the last four digits of the employee's social security number). The required weekly payroll information may be submitted in any form desired. Optional Form WH–347 is available for this purpose from the Wage and Hour Division Web site at
http://www.dol.gov/esa/whd/forms/wh347instr.htm or its successor site. The prime contractor is responsible for the submission of copies of payrolls by all subcontractors. Contractors and subcontractors shall maintain the full social security number and FHWA-1273 -- Revised May 1, 2012
current address of each covered worker, and shall provide them upon request to the contracting agency for transmission to the State DOT, the FHWA or the Wage and Hour Division of the Department of Labor for purposes of an investigation or audit of compliance with prevailing wage requirements. It is not a violation of this section for a prime contractor to require a subcontractor to provide addresses and social security numbers to the prime contractor for its own records, without weekly submission to the contracting agency.
(2) Each payroll submitted shall be accompanied by a “Statement of Compliance,” signed by the contractor or subcontractor or his or her agent who pays or supervises the payment of the
persons employed under the contract and shall certify the following:
(i) That the payroll for the payroll period contains the information required to be provided under §5.5 (a)(3)(ii) of Regulations, 29 CFR part 5, the appropriate information is being maintained under §5.5 (a)(3)(i) of Regulations, 29 CFR part 5, and that such information is correct and complete;
(ii)That each laborer or mechanic (including each helper, apprentice, and trainee) employed on the contract during the payroll period has been paid the full weekly wages earned, without rebate, either directly or indirectly, and that no deductions have been made either directly or indirectly from the full wages earned, other than permissible deductions as set forth in Regulations, 29 CFR part 3;
(iii) That each laborer or mechanic has been paid not less than the applicable wage rates and fringe benefits or cash equivalents for the classification of work performed, as specified in the applicable wage determination incorporated into the contract. (3) The weekly submission of a properly executed certification set forth on the reverse side of Optional Form WH–347 shall satisfy the requirement for submission of the “Statement of Compliance” required by paragraph 3.b.(2) of this section. (4) The falsification of any of the above certifications may subject the contractor or subcontractor to civil or criminal prosecution under section 1001 of title 18 and section 231 of title 31 of the United States Code.
c. The contractor or subcontractor shall make the records required under paragraph 3.a. of this section available for inspection, copying, or transcription by authorized
representatives of the contracting agency, the State DOT, the FHWA, or the Department of Labor, and shall permit such representatives to interview employees during working hours on the job. If the contractor or subcontractor fails to submit the required records or to make them available, the FHWA may, after written notice to the contractor, the contracting agency or the State DOT, take such action as may be necessary to
cause the suspension of any further payment, advance, or guarantee of funds. Furthermore, failure to submit the required records upon request or to make such records available may be grounds for debarment action pursuant to 29 CFR 5.12.
January 2021
EXHIBIT E Page 117 of 130 EXHIBIT 2 961
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
4. Apprentices and trainees
a. Apprentices (programs of the USDOL).
Apprentices will be permitted to work at less than the predetermined rate for the work they performed when they are employed pursuant to and individually registered in a bona fide apprenticeship program registered with the U.S. Department of Labor, Employment and Training Administration, Office of Apprenticeship Training, Employer and Labor Services, or with a State Apprenticeship Agency recognized by the Office, or if a person is employed in his or her first 90 days of probationary employment as an apprentice in such an apprenticeship program, who is not individually registered in the program, but who has been certified by the Office of Apprenticeship Training, Employer and Labor Services or a State Apprenticeship Agency (where appropriate) to be eligible for probationary employment as an apprentice.
The allowable ratio of apprentices to journeymen on the job site in any craft classification shall not be greater than the ratio permitted to the contractor as to the entire work force under the registered program. Any worker listed on a payroll at an apprentice wage rate, who is not registered or otherwise employed as stated above, shall be paid not less than the applicable wage rate on the wage determination for the classification of work actually performed. In addition, any apprentice performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate on the wage determination for the work actually performed. Where a contractor is performing construction on a project in a locality other than that in which its program is registered, the ratios and wage rates (expressed in percentages of the journeyman's hourly rate) specified in the contractor's or subcontractor's registered program shall be observed.
Every apprentice must be paid at not less than the rate specified in the registered program for the apprentice's level of progress, expressed as a percentage of the journeymen hourly rate specified in the applicable wage determination. Apprentices shall be paid fringe benefits in accordance with the provisions of the apprenticeship program. If the apprenticeship program does not specify fringe benefits, apprentices must be paid the full amount of fringe benefits listed on the wage determination for the applicable classification. If the Administrator determines that a different practice prevails for the applicable apprentice classification, fringes shall be paid in accordance with that determination.
In the event the Office of Apprenticeship Training, Employer and Labor Services, or a State Apprenticeship Agency recognized by the Office, withdraws approval of an apprenticeship program, the contractor will no longer be permitted to utilize apprentices at less than the applicable predetermined rate for the work performed until an acceptable program is approved.
b. Trainees (programs of the USDOL).
Except as provided in 29 CFR 5.16, trainees will not be permitted to work at less than the predetermined rate for the work performed unless they are employed pursuant to and individually registered in a program which has received prior approval, evidenced by formal certification by the U.S. Department of Labor, Employment and Training Administration.
FHWA-1273 -- Revised May 1, 2012
The ratio of trainees to journeymen on the job site shall not be greater than permitted under the plan approved by the Employment and Training Administration.
Every trainee must be paid at not less than the rate specified in the approved program for the trainee's level of progress, expressed as a percentage of the journeyman hourly rate specified in the applicable wage determination. Trainees shall be paid fringe benefits in accordance with the provisions of the trainee program. If the trainee program does not mention fringe benefits, trainees shall be paid the full amount of fringe benefits listed on the wage determination unless the Administrator of the Wage and Hour Division determines that there is an apprenticeship program associated with the corresponding journeyman wage rate on the wage determination which provides for less than full fringe benefits for apprentices. Any employee listed on the payroll at a trainee rate who is not registered and participating in a training plan approved by the Employment and Training Administration shall be paid not less than the applicable wage rate on the wage determination for the classification of work actually performed. In addition, any trainee performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate on the wage determination for the work actually performed.
In the event the Employment and Training Administration withdraws approval of a training program, the contractor will no longer be permitted to utilize trainees at less than the applicable predetermined rate for the work performed until an acceptable program is approved.
c. Equal employment opportunity. The utilization of apprentices, trainees and journeymen under this part shall be in conformity with the equal employment opportunity requirements of Executive Order 11246, as amended, and 29 CFR part 30.
d. Apprentices and Trainees (programs of the U.S. DOT).
Apprentices and trainees working under apprenticeship and skill training programs which have been certified by the Secretary of Transportation as promoting EEO in connection with Federal-aid highway construction programs are not subject to the requirements of paragraph 4 of this Section IV. The straight time hourly wage rates for apprentices and trainees under such programs will be established by the particular programs. The ratio of apprentices and trainees to journeymen shall not be greater than permitted by the terms of the particular program.
5. Compliance with Copeland Act requirements. The contractor shall comply with the requirements of 29 CFR part 3, which are incorporated by reference in this contract.
6. Subcontracts. The contractor or subcontractor shall insert Form FHWA-1273 in any subcontracts and also require the subcontractors to include Form FHWA-1273 in any lower tier subcontracts. The prime contractor shall be responsible for the compliance by any subcontractor or lower tier subcontractor with all the contract clauses in 29 CFR 5.5.
7. Contract termination: debarment. A breach of the contract clauses in 29 CFR 5.5 may be grounds for termination of the contract, and for debarment as a contractor and a subcontractor as provided in 29 CFR 5.12.
January 2021
EXHIBIT E Page 118 of 130 EXHIBIT 2 962
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
8. Compliance with Davis-Bacon and Related Act requirements.
All rulings and interpretations of the Davis-Bacon and Related Acts contained in 29 CFR parts 1, 3, and 5 are herein incorporated by reference in this contract.
9. Disputes concerning labor standards. Disputes arising out of the labor standards provisions of this contract shall not be subject to the general disputes clause of this contract. Such disputes shall be resolved in accordance with the procedures of the Department of Labor set forth in 29 CFR parts 5, 6, and 7. Disputes within the meaning of this clause include disputes between the contractor (or any of its subcontractors) and the contracting agency, the U.S.
Department of Labor, or the employees or their representatives.
10. Certification of eligibility.
a. By entering into this contract, the contractor certifies that neither it (nor he or she) nor any person or firm who has an interest in the contractor's firm is a person or firm ineligible to be awarded Government contracts by virtue of section 3(a) of the DavisBacon Act or 29 CFR 5.12(a)(1). b. No part of this contract shall be subcontracted to any person or firm ineligible for award of a Government contract by virtue of section 3(a) of the Davis-Bacon Act or 29 CFR 5.12(a)(1). c. The penalty for making false statements is prescribed in theU.S.
Criminal Code, 18 U.S.C. 1001.
V. CONTRACT WORK HOURS AND SAFETY STANDARDS
ACT
The following clauses apply to any Federal-aid construction contract in an amount in excess of $100,000 and subject to the overtime provisions of the Contract Work Hours and Safety Standards Act.
These clauses shall be inserted in addition to the clauses required by 29 CFR 5.5(a) or 29 CFR 4.6. As used in this paragraph, the terms laborers and mechanics include watchmen and guards.
1. Overtime requirements. No contractor or subcontractor contracting for any part of the contract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives
compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek.
2. Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth inparagraph(1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
FHWA-1273 -- Revised May 1, 2012
3. Withholding for unpaid wages and liquidated damages. The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.
4. Subcontracts. The contractor or subcontractor shall insert in any subcontracts the clauses set forth in paragraph (1.) through (4.) of this section and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (1.) through (4.) of this section.
VI. SUBLETTING OR ASSIGNING THE CONTRACT
This provision is applicable to all Federal-aid construction contracts on the National Highway System.
1. The contractor shall perform with its own organization contract work amounting to not less than 30 percent (or a greater percentage if specified elsewhere in the contract) of the total original contract price, excluding any specialty items designated by the contracting agency. Specialty items may be performed by subcontract and the amount of any such specialty items performed may be deducted from the total original contract price before computing the amount of work required to be performed by the contractor's own organization (23 CFR 635.116).
a. The term “perform work with its own organization” refers to workers employed or leased by the prime contractor, and equipment owned or rented by the prime contractor, with or without operators. Such term does not include employees or equipment of a subcontractor or lower tier subcontractor, agents of the prime contractor, or any other assignees. The term may include payments for the costs of hiring leased employees from an employee leasing firm meeting allrelevant Federal and State regulatory requirements. Leased
employees may only be included in this term if the prime contractor meets all of the following conditions:
(1) the prime contractor maintains control over the supervision of the day-to-day activities of the leased employees;
(2) the prime contractor remains responsible for the quality of the work of the leased employees;
(3) the prime contractor retains all power to accept or exclude individual employees from work on the project; and
(4) the prime contractor remains ultimately responsible for the payment of predetermined minimum wages, the submission of payrolls, statements of compliance and all other Federal regulatory requirements.
b. "Specialty Items" shall be construed to be limited to work that requires highly specialized knowledge, abilities, or equipment not ordinarily available in the type of contracting organizations qualified and expected to bid or propose on the contract as a whole and in general are to be limited to minor components of the overall contract.
January 2021
EXHIBIT E Page 119 of 130 EXHIBIT 2 963
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
2. The contract amount upon which the requirements set forth in paragraph (1) of Section VI is computed includes the cost of material and manufactured products which are to be purchasedor produced by the contractor under the contract provisions.
3. The contractor shall furnish (a) a competent superintendent or supervisor who is employed by the firm, has full authority todirect performance of the work in accordance with the contract requirements, and is in charge of all construction operations (regardless of who performs the work) and (b) such other of its own organizational resources (supervision, management, and engineering services) as the contracting officer determines is necessary to assure the performance of the contract.
4.No portion of the contract shall be sublet, assigned orotherwise disposed of except with the written consent of the contracting officer, or authorized representative, and such consent when given shall not be construed to relieve the contractor of any responsibility for the fulfillment of the contract. Written consent will be given only after the contracting agency has assured that each subcontract is evidenced in writing and that it contains all pertinent provisions and requirements of the prime contract.
5. The 30% self-performance requirement of paragraph (1) is not applicable to design-build contracts; however, contracting agencies may establish their own self-performancerequirements.
VII. SAFETY: ACCIDENT PREVENTION
This provision is applicable to all Federal-aid construction contracts and to all related subcontracts.
1. In the performance of this contract the contractor shall comply with all applicable Federal, State, and local laws governing safety, health, and sanitation (23 CFR 635). The contractor shall provide all safeguards, safety devices and protective equipment and take any other needed actions as it determines, or as the contracting officer may determine, to be reasonably necessary to protect the life and health of employees on the job and the safety of the public and to protect property in connection with the performance of the work covered by the contract.
2. It is a condition of this contract, and shall be made a condition of each subcontract, which the contractor enters into pursuant to this contract, that the contractor and any subcontractor shall not permit any employee, in performance of the contract, to work in surroundings or under conditions which are unsanitary, hazardous or dangerous to his/her health or safety, as determined under construction safety and health standards (29 CFR 1926)
promulgated by the Secretary of Labor, in accordance with Section 107 of the Contract Work Hours and Safety Standards Act (40 U.S.C. 3704).
3. Pursuant to 29 CFR 1926.3, it is a condition of this contract that the Secretary of Labor or authorized representative thereof, shall have right of entry to any site of contract performance to inspector investigate the matter of compliance with the construction safety and health standards and to carry out the duties of the Secretary under Section 107 of the Contract Work Hours and Safety Standards Act (40 U.S.C.3704).
VIII. FALSE STATEMENTS CONCERNING HIGHWAY
PROJECTS
This provision is applicable to all Federal-aid construction contracts and to all related subcontracts.
In order to assure high quality and durable construction in conformity with approved plans and specifications and a high degree of reliability on statements and representations made by engineers, contractors, suppliers, and workers on Federal-aid highway projects, it is essential that all persons concerned with the project perform their functions as carefully, thoroughly, and honestly as possible.
Willful falsification, distortion, or misrepresentation with respect to any facts related to the project is a violation of Federal law. To prevent any misunderstanding regarding the seriousness ofthese and similar acts, Form FHWA-1022 shall be posted on each Federal-aid highway project (23 CFR 635) in one or more places where it is readily available to all persons concerned with the project:
18 U.S.C. 1020 reads as follows:
"Whoever, being an officer, agent, or employee of the United States, or of any State or Territory, or whoever, whether a person, association, firm, or corporation, knowingly makes any false statement, false representation, or false report as to the character, quality, quantity, or cost of the material used or to be used, or the quantity or quality of the work performed or to be performed, or the cost thereof in connection with the submission of plans, maps, specifications, contracts, or costs of construction on any highway or related project submitted for approval to the Secretary of Transportation; or
Whoever knowingly makes any false statement, false
representation, false report or false claim with respect to the character, quality, quantity, or cost of any work performed or to be performed, or materials furnished or to be furnished, in connection with the construction of any highway or related project approved by the Secretary of Transportation; or
Whoever knowingly makes any false statement or false
representation as to material fact in any statement, certificate, or report submitted pursuant to provisions of the Federal-aid Roads Act approved July 1, 1916, (39 Stat. 355), as amended and
supplemented;
Shall be fined under this title or imprisoned not more than 5 years or both."
IX. IMPLEMENTATION OF CLEAN AIR ACT AND FEDERAL
WATER POLLUTION CONTROL ACT
This provision is applicable to all Federal-aid construction contracts and to all related subcontracts.
By submission of this bid/proposal or the execution of this contract, or subcontract, as appropriate, the bidder, proposer, Federal-aid construction contractor, or subcontractor, as appropriate, will be deemed to have stipulated as follows:
1. That any person who is or will be utilized in the
performance of this contract is not prohibited from receiving an award due to a violation of Section 508 of the Clean Water Act or Section 306 of the Clean Air Act.
2. That the contractor agrees to include or cause to be included the requirements of paragraph (1) of this Section X in every subcontract, and further agrees to take such action as the contracting agency may direct as a means of enforcing such requirements.
January 2021
EXHIBIT E Page 120 of 130 EXHIBIT 2 964
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
FHWA-1273 -- Revised May 1, 2012
X. CERTIFICATION REGARDING DEBARMENT, SUSPENSION,
INELIGIBILITY AND VOLUNTARY EXCLUSION
This provision is applicable to all Federal-aid construction contracts, design-build contracts, subcontracts, lower-tier subcontracts, purchase orders, lease agreements, consultant contracts or any other covered transaction requiring FHWA approval or that is estimated to cost $25,000 or more – as defined in 2 CFR Parts 180 and 1200.
1. Instructions for Certification – First Tier Participants:
a. By signing and submitting this proposal, the prospective first tier participant is providing the certification set out below. b. The inability of a person to provide the certification set out below will not necessarily result in denial of participation in this covered transaction. The prospective first tier participant shall submit an explanation of why it cannot provide the certification set outbelow.
The certification or explanation will be considered in connection with the department or agency's determination whether to enter into this transaction. However, failure of the prospective first tier participant to furnish a certification or an explanation shall disqualify such a person from participation in this transaction. c. The certification in this clause is a material representation of fact upon which reliance was placed when the contracting agency determined to enter into this transaction. If it is later determined that the prospective participant knowingly rendered an erroneous certification, in addition to other remedies available to the Federal Government, the contracting agency may terminate this
transaction for cause of default.
d. The prospective first tier participant shall provide immediatewritten notice to the contracting agency to whom this proposal is submitted if any time the prospective first tier participant learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.
e. The terms "covered transaction," "debarred," "suspended," "ineligible," "participant," "person," "principal," and "voluntarily excluded," as used in this clause, are defined in 2 CFR Parts 180 and 1200. “First Tier Covered Transactions” refers to any covered transaction between a grantee or subgrantee of Federal funds and a participant (such as the prime or general contract). “Lower Tier Covered Transactions” refers to any covered transaction under a First Tier Covered Transaction (such as subcontracts). “First Tier Participant” refers to the participant who has entered into a covered transaction with a grantee or subgrantee of Federal funds (such as the prime or general contractor). “Lower Tier Participant” refers any participant who has entered into a covered transaction with a First Tier Participant or other Lower Tier Participants (such as subcontractors and suppliers).
f. The prospective first tier participant agrees by submitting this proposal that, should the proposed covered transaction be entered into, it shall not knowingly enter into any lower tier covered transaction with a person who is debarred, suspended, declared ineligible, or voluntarily excluded from participation in this covered transaction, unless authorized by the department or agency entering into this transaction.
g. The prospective first tier participant further agrees by submitting this proposal that it will include the clause titled "Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion-Lower Tier Covered Transactions," provided by the department or contracting agency, entering into this covered transaction, without modification, in all lower tier covered transactions and in all solicitations for lower tier covered transactions exceeding the $25,000 threshold.
h. A participant in a covered transaction may rely upon a certification of a prospective participant in a lower tier covered transaction that is not debarred, suspended, ineligible, or voluntarily excluded from the covered transaction, unless it knows that the certification is erroneous. A participant is responsible for ensuring that its principals are not suspended, debarred, or otherwise ineligible to participate in covered transactions. To verify the eligibility of its principals, as well as the eligibility of any lower tier prospective participants, each participant may, but is not required to, checkthe Excluded Parties List System website (https://www.epls.gov/), which is compiled by the General Services Administration. i. Nothing contained in the foregoing shall be construed to require the establishment of a system of records in order to render ingood faith the certification required by this clause. The knowledge and information of the prospective participant is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.
j. Except for transactions authorized under paragraph (f) of these instructions, if a participant in a covered transaction knowingly enters into a lower tier covered transaction with a person who is suspended, debarred, ineligible, or voluntarily excluded from participation in this transaction, in addition to other remedies available to the Federal Government, the department or agency may terminate this transaction for cause or default.
* * *
2. Certification Regarding Debarment, Suspension,Ineligibility and Voluntary Exclusion – First Tier Participants:
a. The prospective first tier participant certifies to the best of its knowledge and belief, that it and its principals:
(1) Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participating in covered transactions by any Federal department or agency;
(2) Have not within a three-year period preceding this proposal been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property;
(3) Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State or local) with commission of any of the offenses enumerated in paragraph (a)(2) of this certification; and
(4) Have not within a three-year period preceding this
application/proposal had one or more public transactions (Federal, State or local) terminated for cause or default. b. Where the prospective participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal.
January 2021
EXHIBIT E Page 121 of 130 EXHIBIT 2 965
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
2. Instructions for Certification - Lower Tier Participants:
(Applicable to all subcontracts, purchase orders and other lower tier transactions requiring prior FHWA approval or estimated to cost $25,000 or more - 2 CFR Parts 180 and 1200)
a.By signing and submitting this proposal, the prospective lowertier is providing the certification set out below.
b. The certification in this clause is a material representation of fact upon which reliance was placed when this transaction was entered into. If it is later determined that the prospective lower tier participant knowingly rendered an erroneous certification, in addition to other remedies available to the Federal Government, the department, or agency with which this transaction originated may pursue available remedies, including suspension and/or debarment.
c. The prospective lower tier participant shall provide immediate written notice to the person to which this proposal is submitted if at any time the prospective lower tier participant learns that its certification was erroneous by reason of changed circumstances. d. The terms "covered transaction," "debarred," "suspended," "ineligible," "participant," "person," "principal," and "voluntarily excluded," as used in this clause, are defined in 2 CFR Parts 180 and 1200. You may contact the person to which this proposal is submitted for assistance in obtaining a copy of those regulations. “First Tier Covered Transactions” refers to any covered transaction between a grantee or subgrantee of Federal funds and a participant (such as the prime or general contract). “Lower Tier Covered Transactions” refers to any covered transaction under a First Tier Covered Transaction (such as subcontracts). “First Tier Participant” refers to the participant who has entered into a covered transaction with a grantee or subgrantee of Federal funds (such as the prime or general contractor). “Lower Tier Participant” refers any participant who has entered into a covered transaction with a First Tier Participant or other Lower Tier Participants (such as subcontractors and suppliers). e. The prospective lower tier participant agrees by submitting this proposal that, should the proposed covered transaction be entered into, it shall not knowingly enter into any lower tier covered transaction with a person who is debarred, suspended, declared ineligible, or voluntarily excluded from participation in this covered transaction, unless authorized by the department or agency with which this transaction originated.
f. The prospective lower tier participant further agrees by submitting this proposal that it will include this clause titled "Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion-Lower Tier Covered Transaction," without modification, in all lower tier covered transactions and in all solicitations for lower tier covered transactions exceeding the $25,000 threshold. g. A participant in a covered transaction may rely upon a certification of a prospective participant in a lower tier covered transaction that is not debarred, suspended, ineligible, or voluntarily excluded from the covered transaction, unless it knows that the certification is erroneous. A participant is responsible for ensuring that its principals are not suspended, debarred, or otherwise ineligible to participate in covered transactions. To verify the eligibility of its principals, as well as the eligibility of any lower tier prospective participants, each participant may, but is not required to, check the Excluded Parties List System website (https://www.epls.gov/), which is compiled by the General Services Administration.
FHWA-1273 -- Revised May 1, 2012
h. Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render in good faith the certification required by this clause. The knowledge and normally possessed by a prudent person in the ordinary course of business dealings.
i. Except for transactions authorized under paragraph e of these instructions, if a participant in a covered transaction knowingly enters into a lower tier covered transaction with a person who is suspended, debarred, ineligible, or voluntarily excluded from participation in this transaction, in addition to other remedies available to the Federal Government, the department or agency with which this transaction originated may pursue available remedies, including suspension and/or debarment.
* * * * *
Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion--Lower Tier Participants:
1. The prospective lower tier participant certifies, by submission of this proposal, that neither it nor its principals is presently debarred, suspended, proposed for debarment, declared
ineligible, or voluntarily excluded from participating in covered transactions by any Federal department or agency.
2. Where the prospective lower tier participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal. * * * * *
XI. CERTIFICATION REGARDING USE OF CONTRACT FUNDS
FOR LOBBYING
This provision is applicable to all Federal-aid construction contracts and to all related subcontracts which exceed $100,000 (49 CFR 20).
1. The prospective participant certifies, by signing and submitting this bid or proposal, to the best of his or her knowledge and belief, that:
a. No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in
connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement. b. If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form-LLL, "Disclosure Form to Report Lobbying," in accordance with its instructions.
January 2021
EXHIBIT E Page 122 of 130 EXHIBIT 2 966
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
2. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by 31 U.S.C. 1352.
Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure.
3.The prospective participant also agrees by submitting its bid or proposal that the participant shall require that the language of this certification be included in all lower tier subcontracts, which exceed information of participant is not required to exceed that which is $100,000 and that all such recipients shall certify and disclose accordingly.
January 2021
EXHIBIT E Page 123 of 130 EXHIBIT 2 967
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
12. FEMALE AND MINORITY GOALS
To comply with Section II, "Nondiscrimination," of "Required Contract Provisions Federal-Aid Construction Contracts," the following are for female and minority utilization goals for Federal-aid construction contracts and subcontracts that exceed $10,000:
The nationwide goal for female utilization is 6.9 percent.
The goals for minority utilization [45 Fed Reg 65984 (10/3/1980)] are as follows:
MINORITY UTILIZATION GOALS
Economic
Area
Goal
(Percent)
174 Redding CA:
Non-SMSA (Standard Metropolitan Statistical Area) Counties:
CA Lassen; CA Modoc; CA Plumas; CA Shasta; CA Siskiyou; CA Tehama
6.8 175
Eureka, CA
Non-SMSA Counties:
CA Del Norte; CA Humboldt; CA Trinity
6.6 San Francisco-Oakland-San Jose, CA:
SMSA Counties:
7120 Salinas-Seaside-Monterey, CA 28.9
CA Monterey
7360 San Francisco-Oakland
CA Alameda; CA Contra Costa; CA Marin; CA San Francisco; CA San Mateo
25.6 176
7400 San Jose, CA
CA Santa Clara, CA
7485 Santa Cruz, CA
CA Santa Cruz
19.6 14.9
7500 Santa Rosa
CA Sonoma
9.1 8720 Vallejo-Fairfield-Napa, CA
CA Napa; CA Solano
17.1 Non-SMSA Counties:
CA Lake; CA Mendocino; CA San Benito
23.2 177
Sacramento, CA:
SMSA Counties:
6920 Sacramento, CA
CA Placer; CA Sacramento; CA
Yolo Non-SMSA Counties
CA Butte; CA Colusa; CA El Dorado; CA Glenn; CA Nevada; CA Sierra; CA Sutter; CA Yuba
16.1 14.3
Stockton-Modesto, CA:
SMSA Counties:
5170 Modesto, CA 12.3
178 CA Stanislaus
8120 Stockton, CA
CA San Joaquin
24.3 Non-SMSA Counties
CA Alpine; CA Amador; CA Calaveras; CA Mariposa; CA Merced; CA Tuolumne
19.8 Fresno-Bakersfield, CA
SMSA Counties:
179 0680 Bakersfield, CA
CA Kern
2840 Fresno, CA
19.1 26.1
January 2021
EXHIBIT E Page 124 of 130 EXHIBIT 2 968
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
CA Fresno
Non-SMSA Counties:
CA Kings; CA Madera; CA Tulare
23.6 Los Angeles, CA:
SMSA Counties:
0360 Anaheim-Santa Ana-Garden Grove, CA 11.9
CA Orange
4480 Los Angeles-Long Beach, CA 28.3
180
CA Los Angeles
6000 Oxnard-Simi Valley-Ventura, CA
CA Ventura
6780 Riverside-San Bernardino-Ontario, CA
21.5 19.0
CA Riverside; CA San Bernardino
7480 Santa Barbara-Santa Maria-Lompoc, CA
19.7 CA Santa Barbara
Non-SMSA Counties
CA Inyo; CA Mono; CA San Luis Obispo
24.6 San Diego, CA:
SMSA Counties
181 7320 San Diego, CA
CA San Diego
16.9 Non-SMSA Counties
CA Imperial
18.2 For the last full week of July during which work is performed under the contract, the prime contractor and each non material-supplier subcontractor with a subcontract of $10,000 or more must complete Form FHWA PR-1391 (Appendix C to 23 CFR 230). Submit the forms by August 15.
13. TITLE VI ASSURANCES
During the performance of this Agreement, the contractor, for itself, its assignees and successors in interest (hereinafter collectively referred to as CONTRACTOR) agrees as follows:
a. Compliance with Regulations: CONTRACTOR shall comply with the regulations relative to nondiscrimination in federally assisted programs of the Department of Transportation, Title 49, Code of Federal Regulations, Part 21, as they may be amended from time to time, (hereinafter referred to as the REGULATIONS), which are herein incorporated by reference and made a part of this agreement.
b. Nondiscrimination: CONTRACTOR, with regard to the work performed by it during the AGREEMENT, shall not discriminate on the grounds of race, color, sex, national origin, religion, age, or disability in the selection and retention of sub-applicants, including procurements of materials and leases of equipment. CONTRACTOR shall not participate either directly or indirectly in the discrimination prohibited by Section 21.5 of the Regulations, including employment practices when the agreement covers a program set forth in Appendix B of the Regulations. c. Solicitations for Sub-agreements, Including Procurements of Materials and Equipment: In all solicitations either by competitive bidding or negotiation made by CONTRACTOR for work to be performed under a Sub- agreement, including procurements of materials or leases of equipment, each potential sub-applicant or supplier shall be notified by CONTRACTOR of the CONTRACTOR’S obligations under this Agreement and the Regulations relative to nondiscrimination on the grounds of race, color, or national origin. d. Information and Reports: CONTRACTOR shall provide all information and reports required by the Regulations, or directives issued pursuant thereto, and shall permit access to its books, records, accounts, other sources of information, and its facilities as may be determined by the California Department of Transportation or FHWA to be pertinent to ascertain compliance with such
January 2021
EXHIBIT E Page 125 of 130 EXHIBIT 2 969
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
Regulations or directives. Where any information required of CONTRACTOR is in the exclusive possession of another who fails or refuses to furnish this information, CONTRACTOR shall so certify to the California Department of Transportation or the FHWA as appropriate, and shall set forth what efforts CONTRACTOR has made to obtain the information. e. Sanctions for Noncompliance: In the event of CONTRACTOR’s noncompliance with the nondiscrimination provisions of this agreement, the California Department of Transportation shall impose such agreement sanctions as it or the FHWA may determine to be appropriate, including, but not limited to:
i. withholding of payments to CONTRACTOR under the Agreement within a reasonable period of time, not to exceed 90 days; and/or
ii. cancellation, termination or suspension of the Agreement, in whole or in part. f. Incorporation of Provisions: CONTRACTOR shall include the provisions of paragraphs (1) through (6) in every sub-agreement, including procurements of materials and leases of equipment, unless exempt by the Regulations, or directives issued pursuant thereto.
CONTRACTOR shall take such action with respect to any sub-agreement or procurement as the California Department of Transportation or FHWA may direct as a means of enforcing such provisions including sanctions for noncompliance, provided, however, that, in the event CONTRACTOR becomes involved in, or is threatened with, litigation with a sub-applicant or supplier as a result of such direction, CONTRACTOR may request the California Department of Transportation enter into such litigation to protect the interests of the State, and, in addition, CONTRACTOR may request the United States to enter into such litigation to protect the interests of the United States.
14. USE OF UNITED STATES-FLAG VESSELS (CARGO PREFERENCE ACT) The CONTRACTOR agrees1. To utilize privately owned United States-flag commercial vessels to ship at least 50 percent of the gross tonnage (computed separately for dry bulk carries, dry cargo liners, and tankers) involved, whenever shipping any equipment, material, or commodities pursuant to this contract, to the extent such vessels are available at fair and reasonable rates for United States-flag commercial vessels.
2. To Furnish within 20 days following the date of loading for shipments originating within the United State or within 30 working days following the date of loading for shipments originating outside the United States, a legible copy of a rated “on-board” commercial ocean bill-of-lading in English for each shipment of cargo described in paragraph (1) of this section to both the Contracting Officer (through the prime contractor in the case of subcontractor bills-of-lading) and to the Division of National Cargo, Office of Market Development, Maritime Administration, Washington, DC 20590.
3. To insert the substance of the provisions of this clause in all subcontracts issued pursuant to this contract.
Federal Trainee Program Special Provisions
(to be used when applicable)
15. FEDERAL TRAINEE PROGRAM
For the Federal training program, the number of trainees or apprentices is .
This section applies if a number of trainees or apprentices is specified in the special provisions.
As part of the prime contractor’s equal opportunity affirmative action program, provide on-the-job training to develop full journeymen in the types of trades or job classifications involved.
The prime contractor has primary responsibility for meeting this training requirement.
If the prime contractor subcontracts a contract part, they shall determine how many trainees or apprentices are to be trained by the subcontractor. Include these training requirements in each subcontract.
Where feasible, 25 percent of apprentices or trainees in each occupation must be in their 1st year of apprenticeship or training.
January 2021
zero
EXHIBIT E Page 126 of 130 EXHIBIT 2 970
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
Distribute the number of apprentices or trainees among the work classifications on the basis of the prime contractor’s needs and the availability of journeymen in the various classifications within a reasonable recruitment area.
Before starting work, the prime contractor shall submit to the City/County of :
1. Number of apprentices or trainees to be trained for each classification
2. Training program to be used
3. Training starting date for each classification
The prime contractor shall obtain the City/County of approval for this submitted information before the prime contractor starts work. The City/County of credits the prime contractor for each apprentice or trainee the prime contractor employs on the job who is currently enrolled or becomes enrolled in an approved program.
The primary objective of this section is to train and upgrade minorities and women toward journeyman status.
The prime contractor shall make every effort to enroll minority and women apprentices or trainees, such as conducting systematic and direct recruitment through public and private sources likely to yield minority and women apprentices or trainees, to the extent they are available within a reasonable recruitment area and show that they have made the efforts. In making these efforts, the prime contractor shall not discriminate against any applicant for training.
The prime contractor shall not employ as an apprentice or trainee an employee:
1. In any classification in which the employee has successfully completed a training course leading to journeyman status or in which the employee has been employed as a journeyman
2. Who is not registered in a program approved by the US Department of Labor, Bureau of Apprenticeship and Training
The prime contractor shall ask the employee if the employee has successfully completed a training course leading to journeyman status or has been employed as a journeyman. The prime contractor’s records must show the employee's answers to the questions.
In the training program, the prime contractor shall establish the minimum length and training type for each classification. The City/County of and FHWA approves a program if one of the following is met:
1. It is calculated to:
Meet the your equal employment opportunity responsibilities Qualify the average apprentice or trainee for journeyman status in the classification involved by the end of the training period
2. It is registered with the U.S. Department of Labor, Bureau of Apprenticeship and Training, and it is administered in a way consistent with the equal employment responsibilities of Federal-aid highway construction contracts
The prime contractor shall obtain the State's approval for their training program before they start work involving the classification covered by the program.
The prime contractor shall provide training in the construction crafts, not in clerk-typist or secretarial-type positions. Training is allowed in lower level management positions such as office engineers, estimators, and timekeepers if the training is oriented toward construction applications. Training is allowed in the laborer classification if significant and meaningful training is provided and approved by the division office. Off-site training is allowed if the training is an integral part of an approved training program and does not make up a significant part of the overall training.
January 2021
Stockton
Stockton
Stockton
Stockton
EXHIBIT E Page 127 of 130 EXHIBIT 2 971
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language
The City/County of reimburses the prime contractor 80 cents per hour of training given an employee on thiscontract under an approved training program:
1. For on-site training
2. For off-site training if the apprentice or trainee is currently employed on a Federal-aid project and prime contractor does at least one of the following:
a. Contribute to the cost of the training
b. Provide the instruction to the apprentice or trainee c. Pay the apprentice's or trainee's wages during the off-site training period
3. If the prime contractor complies with this section.
Each apprentice or trainee must:
1. Begin training on the project as soon as feasible after the start of work involving the apprentice's or trainee's skill
2. Remain on the project as long as training opportunities exist in the apprentice's or trainee's work classification or until the apprentice or trainee has completed the training program The prime contractor shall furnish the apprentice or trainee with a copy of the program that the prime contractor will comply with in providing the training
January 2021
Stockton
EXHIBIT E Page 128 of 130 EXHIBIT 2 972
Appendix E of the Title VI Assurances
(US DOT Order 1050.2A)
During the performance of this contract, the contractor, for itself, its assignees, and successors in interest (hereinafter referred to as the “contractor”) agrees to comply with the following nondiscrimination statutes and authorities; including but not limited to:
Pertinent Nondiscrimination Authorities:
• Title VI of the Civil Rights Act of 1964 (42 U.S.C. § 2000d et seq., 78 stat. 252), (prohibits discrimination on the basis of race, color, national origin); and 49 CFR Part 21.
• The Uniform Relocation Assistance and Real Property Acquisition Policies Act of 1970, (42 U.S.C. § 4601), (prohibits unfair treatment of persons displaced or whose property has been acquired because of Federal or Federal-aid programs and projects);
• Federal-Aid Highway Act of 1973, (23 U.S.C. § 324 et seq.), (prohibits discrimination on the basis of sex);
• Section 504 of the Rehabilitation Act of 1973, (29 U.S.C. § 794 et seq.), as amended, (prohibits discrimination on the basis of disability); and 49 CFR Part 27;
• The Age Discrimination Act of 1975, as amended, (42 U.S.C. § 6101 et seq.), (prohibits discrimination on the basis of age);
• Airport and Airway Improvement Act of 1982, (49 U.S.C. § 4 71, Section 4 7123), as amended, (prohibits discrimination based on race, creed, color, national origin, or sex);
• The Civil Rights Restoration Act of 1987, (PL 100-209), (Broadened the scope, coverage and applicability of Title VI of the Civil Rights Act of 1964, The Age Discrimination Act of 1975 and Section 504 of the Rehabilitation Act of 1973, by expanding the definition of the terms “programs or activities” to include all of the programs or activities of the Federal-aid recipients, subrecipients and contractors, whether such programs or activities are Federally funded or not);
• Titles II and III of the Americans with Disabilities Act, which prohibit discrimination on the basis of disability in the operation of public entities, public and private transportation systems, places of public accommodation, and certain testing entities (42 U.S.C. §§ 12131-12189) as implemented by Department of Transportation regulations at 49 C.F.R. parts 37 and 38;
EXHIBIT F Page 129 of 130 EXHIBIT 2 973
• The Federal Aviation Administration's Nondiscrimination statute (49 U.S.C. § 47123) (prohibits discrimination on the basis of race, color, national origin, and sex);
• Executive Order 12898, Federal Actions to Address Environmental Justice in Minority Populations and Low-Income Populations, which ensures discrimination against minority populations by discouraging programs, policies, and activities with disproportionately high and adverse human health or environmental effects on minority and low-income populations; • Executive Order 13166, Improving Access to Services for Persons with Limited English Proficiency, and resulting agency guidance, national origin discrimination includes discrimination because of limited English proficiency (LEP). To ensure compliance with Title VI, you must take reasonable steps to ensure that LEP persons have meaningful access to your programs (70 Fed. Reg. at 74087 to 74100);
• Title IX of the Education Amendments of 1972, as amended, which prohibits you from discriminating because of sex in education programs or activities (20 U.S.C. 1681 et seq).
EXHIBIT F Page 130 of 130 EXHIBIT 2 974
EXHIBIT 2 975
EXHIBIT 2 976
EXHIBIT 2 977
EXHIBIT 2 978
City of Stockton
Legislation Text
File #: 22-0675, Version: 1
APPROVE MOTION TO AWARD A PROFESSIONAL SERVICES CONTRACT FOR THE HSIP 10 -
LEFT-TURN POCKETS PROJECT
RECOMMENDATION
It is recommended that the City Council approve a motion to:
1. Award a Professional Services Contract to Siegfried Engineering, Inc. of Stockton, CA, in the amount of $141,700, for the design of the HSIP 10 - Left-Turn Pockets, Project No.
WT22046/Federal Project No. HSIPSL-5008(195).
2. Approve findings pursuant to Stockton Municipal Code section 3.68.070 in support of an exception to the competitive bidding process.
It is also recommended that the City Manager be authorized to take appropriate and necessary actions to carry out the purpose and intent of this motion.
Summary
The project will install a separate left-turn lane, upgrade signals, and install high friction surface treatment at the intersection of Harding Way and Lincoln Street and at the intersection of Harding Way and Pacific Avenue/Madison Street (Attachment A). The project was approved for Highway Safety Improvement Program (HSIP) funds and included in the 2021-26 Five-Year Capital Improvement Plan (CIP).
On March 18, 2022, the City advertised a Request for Proposals (RFP) for design of the HSIP 10 - Left-Turn Pockets project. On April 26, 2022, two firms submitted proposals for this project. The Selection Committee evaluated the proposals and found Siegfried Engineering, Inc. of Stockton, CA, to be the most qualified and highest ranked firm.
It is recommended that Council approve a motion authorizing the City Manager to execute a Professional Services Contract in the amount of $141,700 to Siegfried Engineering, Inc. It is anticipated that the design will be completed by summer 2023.
DISCUSSION
Background
The HSIP is a federal-aid program established to achieve a significant reduction in traffic fatalities and serious injuries on all public roads. Caltrans, Division of Local Assistance, manages California's local agency share of HSIP funds. HSIP focuses on infrastructure projects with nationally recognized City of Stockton Page 1 of 3 Printed on 9/7/2022
powered by Legistar™
979
File #: 22-0675, Version: 1
crash reduction factors. Local HSIP projects are prioritized based on crash experience, benefit from counter measures, or other data-supported means.
Senate Bill 137 (Chapter 639 of the 2019 Statues) added Section 182.85 to the Streets and Highways Code that authorizes Caltrans to allow up to $100 million of federal local assistance funds to be exchanged for non-federal State Highway Account (SHA) funds. The city, county, or other eligible recipients receiving exchanged funding (federal to State) must use the funding on projects for purposes for which the federal local assistance funds were originally intended. As a result, HSIP Cycle 10 projects are State funded.
The City submitted nine grant applications to Caltrans for Cycle 10 of the HSIP grant program in October 2020. One of the applications was for the HSIP 10 - Left-Turn Pockets project.
The HSIP 10 - Left-Turn Pockets project will install a separate left-turn lane, upgrade signals, and install high friction surface treatment at the intersection of Harding Way and Lincoln Street and at the intersection of Harding Way and Pacific Avenue/Madison Street (Attachment A). These identified safety improvement measures will reduce left-turn conflicts and enhance visibility.
In March 2021, the HSIP 10 - Left-Turn Pockets, Project No. WT22046/Federal Project No. HSIPSL5008(195), was approved for HSIP funding in the amount of $243,900 for design and construction.
This project is 90 percent State funded, and a 10 percent local match is required as part of the grant.
The project was included in the 2021-26 Five-Year CIP.
Since this project is funded with SHA funds, Disadvantaged Business Enterprise program rules do not apply.
Present Situation
On March 18, 2022, the City advertised an RFP for design of the HSIP 10 - Left-Turn Pockets, Project No. WT22046/Federal Project No. HSIPSL-5008(195). On April 26, 2022, two proposals were received from the following firms:
· Siegfried Engineering, Inc. (Stockton, CA)
· CSG, Inc. (Sacramento, CA)
A Selection Committee evaluated and ranked all proposals based on each firm’s understanding of work, experience with similar kinds of projects, staff qualifications, technical ability, project approach, and familiarity of State procedures.
Siegfried Engineering, Inc. received the highest ranking, based on the noted criteria, and was determined to be the most qualified firm for this project. Staff negotiated a fee in the amount of $141,700 with Siegfried Engineering, Inc. for design services. The negotiated fee is approximately seven percent of the total project cost, which is reasonable for a project of this type and complexity.
Staff recommends that Council approve a motion to award a Professional Services Contract in the amount of $141,700 to Siegfried Engineering, Inc. for design services of the HSIP 10 - Left-Turn Pockets project (Attachment B). It is anticipated that the design will be completed by summer 2023.
City of Stockton Page 2 of 3 Printed on 9/7/2022
powered by Legistar™
980
File #: 22-0675, Version: 1
Findings
Pursuant to Stockton Municipal Code (SMC) section 3.68.070, Council may approve findings which support an exception to the competitive bidding process. These findings include:
1. The City does not have sufficient staff and expertise to design this project.
2. Use of the RFP process is appropriate for this Professional Services Contract because it relies on the evaluation of professional qualifications and performance as the basis for selection of a vendor. Use of this criteria helps ensure selection of a vendor that will provide the highest quality professional service, which is in the public interest.
3. The City negotiated a contract following solicitation of competitive proposals in accordance with SMC section 3.68.070.A.3.
FINANCIAL SUMMARY
There is sufficient funding in the HSIP 10 - Left-Turn Pockets, Project No. WT22046 (formerly PW2246)/Federal Project No. HSIPSL-5008(195), Account No. 4510-000-800007-300-000-30-45-000 -000, to award a Professional Services Contract in the amount of $141,700 to Siegfried Engineering, Inc. for the design of the project.
There is no impact to the City’s General Fund or any other unrestricted fund as a result of taking the recommended action.
Attachment A - Project Location Map
Attachment B - Professional Services Contract with Siegfried Engineering, Inc.
City of Stockton Page 3 of 3 Printed on 9/7/2022
powered by Legistar™
981
HSIP 10 - Left-Turn Pockets, Project No. WT22046/
Federal Project No. HSIPSL-5008(195)
Stockton
Project
Location
Harding Way
Pacific
Lincoln St.
Pershing Ave
Miner Ave
El Dorado St
Ave
Legend
= W. Harding Way @ Pacific Ave
= W. Harding Way @ N. Lincoln St
ATTACHMENT A
Project Location Map
982
Professional Services Contract – SIEGFRIED ENGINEERING, INC. – PROJECT NO. WT22046/ FEDERAL PROJECT NO. HSIPSL-5008(195)
(Updated 02/28/18)
PROFESSIONAL SERVICES CONTRACT
THIS CONTRACT is entered into this day of 2022, between the CITY OF STOCKTON, a municipal corporation (“City”), and SIEGFRIED ENGINEERING, INC. whose address is 3428 BROOKSIDE ROAD, STOCKTON, CA 95219 (“Consultant”) for the HSIP 10 - LEFT-TURN POCKETS (PROJECT NO. WT22046/ FEDERAL PROJECT NO. HSIPSL-5008(195)), hereinafter referred to as "Project".
RECITALS
A. Consultant represents that it is licensed in the State of California and is qualified to provide the services proposed in the SCOPE OF WORK section of this Contract.
B. City finds it necessary and advisable to use the services of the Consultant for the purposes provided in this Contract.
NOW THEREFORE, in consideration of the mutual promises, covenants, and conditions in this Contract, City and Consultant agree as follows:
1. SCOPE OF SERVICES. Subject to the terms and conditions set forth in this Contract, Consultant shall undertake and complete the services described in Exhibit A. Consultant shall provide said services at the time, place, and in the manner specified in Exhibit A and compatible with the standards of the profession. Consultant agrees that it shall produce a fully complete project that is acceptable to the City.
2. COMPENSATION. City shall pay Consultant for services outlined in Exhibit A according to the fee not to exceed the schedule detailed in Exhibit B, which is attached to this Contract and incorporated by this reference. Consultant agrees this fee is for full remuneration for performing all services and furnishing all staffing and materials called for in the scope of services. The payments shall be made on a monthly basis upon receipt and approval of Consultant’s invoice. Total compensation for services and reimbursement for costs shall not exceed $141,700.00 or as otherwise mutually agreed to in a Contract Amendment.
3. INSURANCE. During the term of this Contract, Consultant shall maintain in full force and effect at its own cost and expense the insurance coverage as set forth in the attached Exhibit D and shall otherwise comply with the other provisions of Exhibit D.
4. INDEMNITY AND HOLD HARMLESS. With the exception that this section shall in no event be construed to require indemnification by Consultant to a greater extent than permitted under the public policy of the State of California, Consultant shall
ATTACHMENT B
983
Professional Services Contract – SIEGFRIED ENGINEERING, INC. – PROJECT NO. WT22046/ FEDERAL PROJECT NO. HSIPSL-5008(195)
(Updated 02/28/18)
indemnify, and hold harmless City, its Mayor, Council, officials, and employees from and against any and all claims and causes of action which result in liabilities, judgments, awards, losses, damages, expenses, and costs (including reasonable attorneys’ fees, expert and consultant fees, and other expenses of litigation) including, but not limited to, death or injury to persons, or damage to property, which arise out of any violation of federal, state, or municipal law or ordinance, to the extent damages are caused by the Consultant’s negligent services provided under this Agreement, or are in any way caused by the negligent performance of work by the Consultant or Consultant’s officers, agents, employees, or subcontractors. Consultant shall not be obligated to indemnify or defend City for claims finally determined by a court of law or arbitrator to arise from the negligence or willful misconduct of the City. It is the intent of the Parties that this indemnity obligation is at least as broad as is permitted under California law. To the extent California Civil Code sections 2782, et seq., limit the defense or indemnity obligations of Consultant to City, the intent hereunder is to provide the maximum defense and indemnity obligations allowed by Consultant under the law. The indemnity set forth in this section shall not be limited by insurance requirements or by any other provision of this Agreement.
With the exception that this section shall in no event be construed to require indemnification by Consultant to a greater extent than permitted under the public policy of the State of California, and in addition to the other indemnity obligations in this Agreement, Consultant shall indemnify, defend, and hold harmless City, its Mayor, Council, officials, representatives, and employees from and against claims, losses, expenses, and costs including, but not limited to, reasonable attorneys’ fees, arising out of any claim brought against the City by an employee of Consultant, regardless of whether such claim may be covered by any applicable workers compensation insurance.
Consultant’s indemnification obligation is not limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for the Consultant under workers’ compensation acts, disability acts, or other employee benefit acts.
5. SCHEDULE AND TERM. Consultant shall perform the scope of work as described in Exhibit A according to the schedule detailed in Exhibit C, which is attached to this Contract and incorporated by this reference. This Contract shall commence on the date written above and shall expire on October 30, 2027, unless extended by mutual agreement through the issuance of a Contract Amendment. a. Invoices submitted by Consultant to City must contain a brief description of work performed, time used, and include the City project number. Payment shall be made within thirty (30) days of approval of invoice by City. b. Upon completion of work and acceptance by City, Consultant shall have sixty (60) days in which to submit final invoicing for payment. An extension may be granted by City upon receiving a written request thirty (30) days in advance of said time limitation. City shall have no obligation or liability to pay any invoice for work performed which Consultant fails or neglects to
Professional Services Contract – SIEGFRIED ENGINEERING, INC. – PROJECT NO. WT22046/ FEDERAL PROJECT NO. HSIPSL-5008(195)
(Updated 02/28/18)
submit within sixty (60) days, or any extension thereof granted by the City, after work is accepted by City.
6. CONFORMANCE TO APPLICABLE LAWS. Consultant shall comply with all applicable federal, State, and Municipal laws, rules, and ordinances. Consultant shall not discriminate in the employment of persons or in the provision of services under this Contract on the basis of any legally protected classification, including race, color, national origin, ancestry, sex or religion of such person.
a. TITLE VI
Title VI of the Civil Rights Act of 1964 requires that “no person in the United States shall, on the grounds of race, color, or national origin, be excluded from participation in, be denied the benefits of, or be subjected to discrimination under any program or activity receiving federal financial assistance.” (42 USC Section 2000d).
http://www.dol.gov/oasam/regs/statutes/titlevi.htm .
The City of Stockton requires compliance with the requirements of Title VI in all of its programs and activities regardless of funding source. b. DISCRIMINATION AND HARASSMENT POLICY
The City of Stockton has a Discrimination and Harassment Policy (Exhibit E). The purpose of this policy is to reaffirm the City’s commitment to demonstrating respect for all individuals by strictly prohibiting discrimination and harassment, including sexual harassment in the workplace, to define the types of behavior and conduct prohibited by this policy, and to set forth a procedure for reporting, investigating, and resolving complaints of discrimination and harassment in the workplace.
c. LABOR STANDARDS PROVISIONS/CALIFORNIA LABOR CODE
The bidder shall understand that conditions set forth in Chapter 1, Part 7, Division 2 of the California Labor Code shall be considered part of the contract
agreement. https://leginfo.legislature.ca.gov/faces/codes_displayText.xht ml?lawCode=LAB&division=2.&title=&part=7.&chapter=1.&article=2. d. PREVAILING WAGE RATES
Consultant and any subcontractor shall pay each employee engaged in the trade or occupation not less than the prevailing hourly wage rate. In accordance with the provisions of Section 1770 of the Labor Code, the
Professional Services Contract – SIEGFRIED ENGINEERING, INC. – PROJECT NO. WT22046/ FEDERAL PROJECT NO. HSIPSL-5008(195)
(Updated 02/28/18)
Director of Department of Industrial Relations of the State of California has determined the general prevailing rates of wages and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for in Section 1773.1, apprenticeship or other training programs authorized by Section 3093 and similar purposes applicable to the work to be done. Consultant performing the work under this contract shall obtain a copy of the wage rate determination and shall distribute copies to each subcontractor. As the wage determination for each craft reflects an expiration date, it shall be the prime Consultant and each subcontractor's responsibility to insure that the prevailing wage rates of concern is current and paid to the employee.
i. The Consultant performing the work shall be responsible for obtaining a copy of the State wage rate determination. State wage rates may be obtained at
http://www.dir.ca.gov/OPRL/pwd/Determinations/Northern/Northern.p df. The Consultant shall be responsible for posting said wage rates at a prominent location at the work site and shall maintain same in a good readable condition for the duration of the work.
ii. Should the Consultant choose to work on a Saturday, Sunday or on a holiday recognized by the Labor Unions, the Consultant shall reimburse the City the actual cost of engineering, inspection, superintendence, and or other overhead expenses which are directly chargeable to the contract. Should such work be undertaken at the request of the City, reimbursement will not be required. To conform strictly with the provisions of Division 2, Part 7, Chapter 1, Article 2, of the Labor Code of the State of California. To forfeit as a penalty to City the sum of TWENTY-FIVE AND NO/100 DOLLARS ($25.00) for each laborer, worker, or mechanic employed by CONTRACTOR, or by any subcontractor under Consultant, in the execution of this contract, for each calendar day during which any laborer, worker, or mechanic is required or permitted to work more than eight (8) hours and who is not paid the general prevailing rate of per diem wages for holiday and overtime work in violation of the provisions of Sections 1770 to 1781 of the Labor Code of the State of California. That all sums forfeited under the provisions of the foregoing sections shall be deducted from the payments to be made under the terms of this contract. iii. PAYROLL RECORDS - The Consultant to whom the contract is awarded shall insure that the prime and each subcontractor will, in accordance with Section 1776 of the Labor Code, maintain certified payroll records. A copy of said records shall be provided with each invoice to the Public Works Department, Attention: Contract
Professional Services Contract – SIEGFRIED ENGINEERING, INC. – PROJECT NO. WT22046/ FEDERAL PROJECT NO. HSIPSL-5008(195)
(Updated 02/28/18)
Compliance Officer. It shall be the Consultant’s responsibility to obtain copies of the current prevailing wage rate determination for all subcontractors. Additionally, certified payroll records must be uploaded to the DIR website as required by labor code.
iv. APPRENTICESHIP STANDARDS - The Consultant shall comply with the provisions established in Section 1777.5 of the Labor Code concerning the 1) certified approval by local joint apprenticeship committees for the employment and training of apprentices, and 2) contribution of funds to administer and conduct apprenticeship programs, if applicable to the job.
7. RIGHTS AND DUTIES OF CITY. City shall make available to Consultant all data and information in the possession of City which both parties deem necessary to complete the work, and City shall actively aid and assist Consultant in obtaining such information as may be deemed necessary from other agencies and individuals.
8. OBLIGATIONS OF CONSULTANT. Throughout the term of this Contract, Consultant represents and warrants that it has or will have at the time this Contract is executed, all licenses, permits, qualifications, insurance, and approvals of whatsoever nature which are legally required for the Consultant to practice its professions, and Consultant shall, at its own cost and expense, keep in effect during the life of this Contract all such licenses, permits, qualifications, insurance, and approvals. Consultant shall meet with the Public Works Director or other personnel of City or third parties as necessary on all matters connected with the carrying out of Consultant’s services. Such meetings shall be held at the request of either party hereto. Consultant further warrants that it will follow the best current, generally accepted and professional practices to make findings, render opinions, prepare factual presentations, and provide professional advice and recommendations regarding this project.
9. OWNERSHIP OF WORK. All reports, drawings, designs, plan review comments, work product, and all other documents completed or partially completed by Consultant in the performance of this Contract shall become and remain the property of the City. Any and all copyrightable subject matter in all materials is hereby assigned to the City and the Consultant agrees to execute any additional documents that may be necessary to evidence such assignment. All materials shall be delivered to the City upon completion or termination of the work under this Contract. If any materials are lost, damaged, or destroyed before final delivery to the City, the Consultant shall replace them at its own expense. Consultant shall keep materials confidential. Materials shall not be used for purposes other than performance of services under this Contract and shall not be disclosed to anyone not connected with these services unless the City expressly provides prior written consent.
Professional Services Contract – SIEGFRIED ENGINEERING, INC. – PROJECT NO. WT22046/ FEDERAL PROJECT NO. HSIPSL-5008(195)
(Updated 02/28/18)
10. CONTRACT AMENDMENTS. City reserves the right to make such alterations as may be deemed necessary or advisable and to require such extra work as may be required for the proper completion of the work contemplated by Consultant. Any such changes will be set forth in a Contract Amendment which will specify, in addition to the work done in connection with the change made, adjustment of contract time, if any, and the basis of compensation for such work. A Contract Amendment will not become effective until approved by the authorized City official.
11. TERMINATION. The City may terminate this Contract at any time by mailing a notice in writing to Consultant. The Contract shall then be deemed terminated and no further work shall be performed by Consultant. If the Contract is so terminated, the Consultant shall be paid for that percentage of work actually completed at the time the notice of termination is received.
12. CONSULTANT STATUS. In performing the obligations set forth in this Contract, Consultant shall have the status of an independent contractor and Consultant shall not be considered to be an employee of the City for any purpose. All persons working for or under the direction of Consultant are its agents and employees, and are not agents of the City. Subcontractors shall not be recognized as having any direct or contractual relationship with the City. The persons engaged in the work, including employees of subcontractors and suppliers, will be considered employees of Consultant.
The Consultant shall be responsible for the work of subcontractors, which shall be subject to the provisions of this Contract. The Consultant is responsible to the City for the acts and omissions of its subcontractors and persons directly or indirectly employed by them. a. If in the performance of this Contract any third persons are employed by Consultant, such persons shall be entirely and exclusively under the direction, supervision, and control of Consultant. All terms of employment including hours, wages, working conditions, discipline, hiring, and discharging or any other term of employment or requirement of law shall be determined by Consultant.
i. It is further understood and agreed that Consultant must issue W-2 forms or other forms as required by law for income and employment tax purposes for all of Consultant’s personnel.
ii. As an independent contractor, Consultant hereby indemnifies and holds City harmless from any and all claims that may be made against the City based upon any contention by any third party that employer-employee relationship exists by reason of this Contract.
13. ASSIGNMENT. Consultant shall not assign, sublet, or transfer this Contract or any interest or obligation in the Contract without the prior written consent of the City,
Professional Services Contract – SIEGFRIED ENGINEERING, INC. – PROJECT NO. WT22046/ FEDERAL PROJECT NO. HSIPSL-5008(195)
(Updated 02/28/18)
and then only upon such terms and conditions as City may set forth in writing. Consultant shall be solely responsible for reimbursing subcontractors.
14. HEADINGS NOT CONTROLLING. Headings used in the Contract are for reference purposes only and shall not be considered in construing this Contract.
15. NOTICES. Any and all notices herein required shall be in writing and shall be sent by certified or registered mail, postage prepaid, addressed as follows:
To Consultant: Siegfried Engineering, Inc. To City: Public Works Director 3428 Brookside Road City of Stockton
Stockton, CA 95219 22 E. Weber Ave., Rm. 301
Stockton, CA 95202
16. LICENSES, CERTIFICATIONS, AND PERMITS. Prior to the City’s execution of this Contract and prior to the Consultant’s engaging in any operation or activity set forth in this Contract, Consultant shall obtain a City of Stockton business license, which must be kept in effect during the term of this Contract. Consultant covenants that it has obtained all certificates, licenses, permits and the like required to perform the services under this Contract.
17. RECORDS AND AUDITS. City reserves the right to periodically audit all charges made by Consultant to City for services under this Contract. Upon request, Consultant agrees to furnish City, or a designated representative, with necessary information and assistance.
Consultant agrees that City or its delegate shall have the right to review, obtain, and copy all records pertaining to performance of the Contract. Consultant agrees to provide City or its delegate with any relevant information requested, and shall permit City or its delegate access to its premises, upon reasonable notice, during normal business hours for the purpose of interviewing employees and inspecting and copying such books, records, accounts, and other material that may be relevant to a matter under investigation for the purposes of determining compliance with this Contract. Consultant agrees to maintain such records for a period of three years from the date that final payment is made.
18. CONFIDENTIALITY. Consultant shall exercise reasonable precautions to prevent the unauthorized disclosure and use of City reports, information or conclusions.
19. CONFLICTS OF INTEREST. Consultant covenants that other than this Contract, Consultant has no financial interest with any official, employee, or other representative of the City. Consultant and its principals do not have any financial interest in real property, sources of income or investment that would be affected in any manner or degree by the performance of Consultant’s services under this Contract. If such an interest arises, Consultant will immediately notify City.
Professional Services Contract – SIEGFRIED ENGINEERING, INC. – PROJECT NO. WT22046/ FEDERAL PROJECT NO. HSIPSL-5008(195)
(Updated 02/28/18)
20. WAIVER. In the event either City or Consultant at any time waive any breach of this Contract by the other, such waiver shall not constitute a waiver of any other or succeeding breach of this Contract, whether of the same or of any other covenant, condition, or obligation.
21. GOVERNING LAW. California law shall govern any legal action pursuant to this Agreement with venue for all claims in the Superior Court of the County of San Joaquin, Stockton Branch or, where applicable, in the federal District Court of California, Eastern District, Sacramento Division.
22. NO PERSONAL LIABILITY. No official or employee of City shall be personally liable to Consultant in the event of any default or breach by City or for any amount due Consultant.
23. INTEGRATION AND MODIFICATION. The response by Consultant to the Request for Proposals and the Request for Proposals on file with the City Clerk are hereby incorporated herein by reference to the extent that such documents do not differ from the provisions and terms of this Contract that shall supersede such response to Request for Proposals. This Contract represents the entire integrated agreement between Consultant and City, supersedes all prior negotiations, representations, or agreements, either written or oral, between the parties, and may be amended only by written instrument signed by Consultant and City. All exhibits and this contract are intended to be construed as a single document. Should any inconsistency occur between the specific terms of this Contract and the attached exhibits, the terms of this Contract will prevail.
24. SEVERABILITY. The provisions of this Contract are severable to the extent that should any of its provisions or terms be declared void in whole or in part by operation of law or agreement of the parties, the remainder of the provisions or terms not expressly declared void shall remain enforceable and in full effect.
25. THIRD PARTY RIGHTS. Nothing in this Contract shall be construed to give any rights or benefits to anyone other than City and Consultant.
26. AUTHORITY. The undersigned hereby represent and warrant that they are authorized by the parties to execute this Contract.
//
//
//
//
//
//
//
//
Professional Services Contract – SIEGFRIED ENGINEERING, INC. – PROJECT NO. WT22046/ FEDERAL PROJECT NO. HSIPSL-5008(195)
(Updated 02/28/18)
IN WITNESS WHEREOF: the parties have executed this Contract the day and year first hereinabove written.
CITY OF STOCKTON SIEGFRIED ENGINEERING, INC.
By: By:
HARRY BLACK Signature
CITY MANAGER
ATTEST:
Print Name
BY:
ELIZA R. GARZA, CMC Title:
CITY CLERK
APPROVED AS TO FORM:
BY:
DEPUTY CITY ATTORNEY
Paul Schneider
President
ATTACHMENT B 991
Left Turn Lanes Detailed Work Plan
TASK 1 BACKGROUND RESEARCH
Siegfried will conduct a field reconnaissance of the project area. Siegfried will review and verify the location and type of existing improvements, equipment, bus zone locations, intersection geometrics, posted speed limit signs, on-street parking, and bus route movements. Siegfried will review collision reports, sight distance, approach speed, traffic volume, and other geometrical and operational characteristics for the project. Siegfried will prepare a topographic survey of the intersection for use throughout the design process.
Siegfried will collect traffic counts for the AM (7-9), Midday (11-1), and PM(4-6) peaks times on all legs of the intersection to guide the turn lane design.
TASK 2 UTILITY COORDINATION
Siegfried will be responsible for performing utility investigations and coordination with utility owners throughout the project development process. Siegfried will be present at all necessary meeting with each utility owner. Siegfried will be responsible for, but not limited to, the following:
Prepare a project limits map and request utility information from each utility owner within the area of work.
• Prepare Utility Letter “A” during preliminary design phase to the affected utility owners for City to review and approve prior to transmitting to utility owners. Information on existing utilities obtained as a result of the “A” letter will be transferred to base maps in both plan and profile view. A copy of the utility data obtained from utility owners will be provided to the City and the originals will be filed in the project files.
• Prepare Utility Letter “B” during 65% design phase to the affected utility owners for City to review and approve prior to transmitting to utility owners. Two sets of half-sized 65% plans will be provided to each utility owner as an attachment to the letter. The letter will request that utility owners verify any utility conflicts with proposed improvements and indicate whether any future utilities are proposed in the area that may require accommodation through the improved area. Information on existing utilities obtained as a result of the “B” letter will be used to determine potential utility conflicts and to resolve the conflicts identified. A copy of the utility data obtained from utility owners will be provided to the City and the originals will be filed in the project files.
• Prepare Utility Letter “C” during 100% design phase to the affected utility owners for City to review and approve prior to transmitting to utility owners. Two sets of half-sized 100% plans will be provided to each utility owner as an attachment to the letter. The letter will indicate to the utility owners whether any changes have been made to the project plans since the Utility Letter “B” and will request written confirmation of utility relocations and utility relocation schedule. A copy of the utility data obtained from utility owners will be provided to the City and the originals will be filed in the project files.
Siegfried will meet with utility companies as needed to ensure that conflicts are identified, and relocations performed if necessary.
EXHIBIT A Page 10 of 37 ATACHMENT B 992
TASK 3 PLANS, SPECIFICATIONS, & ESTIMATE (PS&E)
Siegfried will prepare and complete PS&E documents, which include design improvement plans for demolition, grading, striping, electrical, drainage, paving, staging, erosion control, and other civil details as well as technical specifications, and engineer’s estimate. Siegfried will prepare a base map showing existing information to facilitate the design of all the necessary improvements in accordance with the City of Stockton Standard Plans and Specifications, Caltrans Standard Specifications, and current MUTCD, as appropriate. The base map limits will be sufficient to cover all necessary improvements withing the project area. The project shall use the existing curb-to-curb width. Siegfried will conform the design to comply with Americans with Disabilities Act (ADA.) If dual accessible ramps cannot be installed for this project, Siegfried will prepare an internal memo for the project file and provide justifications.
The survey for design shall cover overhead utilities and at minimum the areas shown in the vicinity map.
The design shall include drawing detail showing traffic signal controller, pre-emptive/TSP system and video camera interconnects using communication equipment in City Hall and in the traffic signal cabinet.
If required, Siegfried will include the City’s up to date communication criteria to establish communication between the Traffic Management Center (TMC) and the traffic signal controller, preemptive/TSP system, and video camera via single mode fiber line in their design.
Siegfried will provide PS&E documents to the City for review at 30%, 65%, 95%, and 100% completion stage. Siegfried will provide one set of full size, 24”x36”, plans (PDF), one set of specifications (PDF, Word) and the engineer’s estimate (PDF/Excel) at each design stage. Siegfried will utilize Bluebeam software for the PDF submittals. With each stage of review, Siegfried will review and incorporate comments, create a comment matrix to track all comments, and provide a signed Quality Control Checklist. Any comments not incorporated into the submittals shall be tracked and justification provided in the comment matrix. Siegfried will provide the City electronic copies of the PS&E after the 100% comments have been incorporated as a final check prior to plotting the plans on mylars.
Siegfried will provide all correspondence and work products for City files.
TASK 3.1 30% PS&E
At a minimum the 30% design should include a basic geometric configuration of roadway layouts and cross sections at the intersection. Consultant to consider turning motions of Stockton Unified School District, Stockton Fire Department, San Joaquin Regional Transit District, and Stockton Waste Management vehicles, as well as semi-trucks with trailers when designing the project.
TASK 3.2 65% PS&E
At a minimum the design should be developed far enough to identify locations of utilities, geometric features, and other design elements. Prepare the plans such that the environmental documents may be completed with the 65% submittal. Consultant to consider turning motions of Stockton Unified School District, Stockton Fire Department, San Joaquin Regional Transit District, and Stockton Waste Management vehicles, as well as semi-trucks with trailers when designing the project. Consultant shall coordinate with PG&E for any connection requirements.
EXHIBIT A Page 11 of 37 ATACHMENT B 993
TASK 3.3 95% PS&E
Project estimates and specifications shall be included at this stage. The review comments from the 65% submittal shall be itemized and a written response to the comments shall be prepared in a comment matrix. The original red-line mark-up from the City shall be returned with the succeeding submittal.
TASK 3.4 100% PS&E
Complete design revisions from preliminary design. Detailed project estimates and specifications shall be included at
this stage. Consultant shall coordinate with PG&E for any additional connection requirements. Siegfried will provide the necessary final PS&E documents in a bid-ready form. Project files and the Project Engineer’s/Resident Engineer’s file will also be submitted with the Final PS&E.
TASK 3.5 QUALITY CONTROL
The PS&E shall be subject to quality control reviews before submittal. These reviews will assure conformance to City and Caltrans Standards, as well as minimize typographical omissions. Siegfried will provide a signed Quality Control Checklist at the time of each deliverable submittal.
TASK 4 PUBLIC OUTREACH
Siegfried will research and develop a stakeholder database of potentially interested parties, which will be updated throughout the project with names from the public meeting(s), sign-in, information from the project team and from telephone, email and personal contact as well as the preferred method of contact, and potential key interest/concerns. The database will be coded according to the interest and involvement with the project. Among the groups on the stakeholders list will be the following:
• Council member and other elected and appointed officials • Residents and property owners adjacent to the proposed project area • Businesses and other establishments adjacent to the project area • Emergency Responders
• School District
• Public Transit
There will be a minimum of two (2) Public Information Meeting(s) to present concepts and design features to the neighboring residents and businesses, and to the public. Siegfried will collaborate with City staff will determine a location near the project site to have the meeting. The meeting(s) will be designed primarily to provide information on the project features, goals, and construction impacts.
Siegfried will schedule the meeting(s) and make all meeting arrangements; write, design, and issue meeting notices by first-class mail to stakeholders and by third-class mail to nearby residents; prepare agendas, sign-in sheets, comment sheets, signage, and other print materials; facilitate meeting proceedings; venue coordination, prepare exhibits and a PowerPoint presentation for each meeting to illustrate concepts and plan elements; record public comments/assist with appropriate responses; and prepare a detailed meeting report. Siegfried will administer Title VI compliance documentation at the public meeting. Following the meeting, Siegfried will develop a summary of the meeting which will include all feedback received and photography. The meeting should be scheduled after the 65% plans and environmental documents have been prepared.
EXHIBIT A Page 12 of 37 ATACHMENT B 994
TASK 5 COORDINATION/MEETINGS
Siegfried will attend a design kick-off meeting and other subsequent meeting with the City, as needed, to finalize the design. Siegfried will attend a pre-construction meeting, a post construction meeting, and meet and assist staff during construction
as required. Siegfried will prepare and provide a comprehensive work schedule to reflect the timeframe for each task of
the proposed scope of work, utilizing Microsoft Project. The project schedule shall show the tasks, duration, milestones, assignments, critical paths, successors, predecessors, and other relevant data. The project schedule shall be maintained and updated monthly throughout the duration of the PS&E phase of the project. An updated project schedule shall be submitted after each review.
TASK 6 DESIGN SUPPORT DURING CONSTRUCTION
As part of the proposal, Consultant shall include bid support services that consist of assisting the City in addressing inquiries submitted during bidding and design support during construction phase of the project.
Consultant shall include bid support services that consist of assisting the City in responding to all Requests for Information (RFI) during the project advertisement phase as well as preparing any Letters of Clarification (LOC) that are needed.
Consultant shall include services for design support during construction which include, responding to RFI’s, submittal reviews and approvals, altering project plans to address any design changes necessary during construction or inconsistencies, assist City staff in reviewing Contract Change Orders, attend construction and field meetings if necessary, assist the City Inspector with specific design-related issues during construction and any needed consultation with the construction contractor and/or the City Project Manager throughout construction.
TASK 7 AS-BUILT DRAWINGS
Siegfried will prepare as built drawings upon receipt of red-lines from the contractor. Siegfried will provide electronic
copies of the As-built sheets. As-built record drawings shall reflect change orders, accommodations, and adjustments to all improvements constructed. Prior to accepting the As-built Plans, City staff will review the Record Drawings and electronic files to conform that they reflect what has been constructed.
Electronic files of the As-built drawings (PDF format) and CAD (DWG or DXF format) shall be provided in addition to the original As-Built Mylars. Changes will be reflected on the mylars either by hand or a new printed sheet.
TASK 8 PRESERVING & PERPETUATING SURVEY MONUMENTS & RIGHTS OF ENTRY Siegfried will identify, list, and show existing survey monuments on construction plans. Siegfried will include language in the PS&E package to preserve all monumentation affected by the work being performed in accordance with Section 8771 of the Professional Land Surveyors Act in the Business and Professionals Code of the State of California.
Siegfried will sign the Acknowledgment of Monument Preservation form.
EXHIBIT A Page 13 of 37 ATACHMENT B 995
Siegfried will assist the City in obtaining rights of entry documentation from property owners where work is required on their property. Siegfried will send out letters to property owners with a right of entry form (provided by the City) and any exhibits needed to adequately portray the work to be done.
These documents are meant for minor conform work that is needed to conform the adjacent properties to the final project.
EXHIBIT A Page 14 of 37 ATACHMENT B 996
Siegfried TJKM
PROJECT
TOTAL
Task 1 Background Research & Memorandum
1.1 Background Research and Survey $20,700 $3,000 $23,700 Task 2 Utility Coordination
2.1 Coordination $3,000 $3,000
Task 3 PS&E's
3.1 30% Submittal $9,000 $8,000 $17,000
3.2 65% Submittal $12,000 $9,000 $21,000
3.3 95% Submittal $13,000 $7,000 $20,000
3.4 100% and Final Submittals $7,000 $5,800 $12,800
3.5 Quality Control $6,600 $2,600 $9,200
Task 4 Public Outreach
4.1 Communication $3,000 $3,000
4.2 Meetings $9,000 $9,000
Task 5 Coordination and Meetings
5.1 Project Management $5,000 $5,000
5.2 Monthly Meetings $4,000 $1,000 $5,000
Task 6 Design Support During Construction
6.1 Bidding $1,500 $500 $2,000
6.2 Construction Support $4,000 $3,000 $7,000
Task 7 As Built Drawings
7.1 As Built Drawings $1,000 $500 $1,500
Task 8 Preserving Survey Monuments
8.1 Preserving Survey Monuments $1,500 $1,500
8.2 Rights of Entry $1,000 $1,000
Total Cost $101,300 $40,400 $141,700
Proposed Fee for the City of Stockton
Left Turn Lanes Project
EXHIBIT B Page 15 of 37 ATACHMENT B 997
Proposed Fee for the City of Stockton Left Turn Lanes Project Consultant:
Siegfried
Direct Labor
Job Title Name Hours Actual Hourly Rate Total
Managing Principal Paul Schneider 8 $104.00 $832.00
Principal QA/QC Adam Merrill 24 $98.50 $2,364.00
Principal Survey Kevin Genasci 8 $98.50 $788.00
Associate Nathan Berend 120 $79.33 $9,519.60
Associate Public Outreach Chris Kay 60 $53.00 $3,180.00 Engineer II Lauren Sensibaugh 80 $36.05 $2,884.00
Engineer II Monica Poncini 80 $36.05 $2,884.00
Senior Technician Mike Kincaid 60 $40.86 $2,451.60
Party Chief Scott Soares 20 $66.00 $1,320.00
Labor Costs
a) Direct Labor Cost $26,223.20
b) Anticipated Salary Increases $0
c) Total Direct Labor Costs [(a)+(b)] $26,223.20
Fringe Benefits
d) Fringe Benefits Rate 70.85%
e) Total Fringe Benefits [(c) x (d)] $18,579.14
Indirect Costs
f) Overhead Rate 74.17%
h) General and Administrative Rate 74.21%
g) Overhead [(c)x(f)] $19,449.75
i) Gen & Admin [(c)x(h)] $19,460.24
j) Total Indirect Costs [(e)+(g)+(i)] $57,489.12
Fee (Profit)
q) Rate 10%
k) Total Fixed Profit $8,371.23
Other Direct Costs (ODC)
Description Unit(s) Unit Cost Total
Mailers 1500.00 $0.250 $375.00
Plotting (sf) 3365.8 $0.250 $841.45
Traffic Counts 1 $8,000 $8,000.00
l) Total Other Direct Costs $9,216.45
Subconsultants
TJKM
m) Total Subconsultants
Total Siegfried Cost $101,300.00 71.49%
Total Project Cost $141,700.00
$40,400.00
$40,400.00
$0.00
EXHIBIT B Page 16 of 37 ATACHMENT B 998
Proposed Fee for the City of Stockton Left Turn Lanes Project Sub-Consultant:
TJKM
Direct Labor
Job Title Name Hours Actual Hourly Rate Total
PIC Rtua Jariwala 4 $91.54 $366.16
QA/QC Sayed Fakry 12 $84.18 $1,010.16
PM Rutvij Patel 72 $71.61 $5,155.92
PE Anna Highsmith 106 $44.37 $4,703.22
PE Raymoundo Floris 110 $35.09 $3,860
Labor Costs
a) Direct Labor Cost $15,095.36
b) Anticipated Salary Increases $0 Less than 1 year project c) Total Direct Labor Costs [(a)+(b)] $15,095.36
Fringe Benefits
d) Fringe Benefits Rate 32.71%
e) Total Fringe Benefits [(c) x (d)] $4,937.69
Indirect Costs
f) Overhead Rate 63.49%
h) General and Administrative Rate 45.00%
g) Overhead [(c)x(f)] $9,584.04
i) Gen & Admin [(c)x(h)] $6,792.91
j) Total Indirect Costs [(e)+(g)+(i)] $21,314.65
Fee (Profit)
q) Rate 10%
k) Total Fixed Profit $3,641.00
Other Direct Costs (ODC)
Description Unit(s) Unit Cost Total
l) Travel/Mileage Costs 640.37 $0.545 $349.00
m) Mailers, AV, Rental Space 0 $1.29 $0.00
n) Printing 0 $0.20 $0.00
o) Subconsultant Costs
p) Total Other Direct Costs [(l)+(m)+(n)+(o)] $349.00
Total Cost $40,400.00
EXHIBIT B Page 17 of 37 ATACHMENT B 999
22 CIVIL Ŷ STRUCTURAL Ŷ LANDSCAPE ARCHITECTURE Ŷ SURVEYING Ŷ PLANNING Ŷ ATHLETIC FACILITY DESIGN 3428 Brookside Road, Stockton, CA 95219 Ŷ (t) 209.943.2021 (f) 209.942.0214 Ŷ siegfriedeng.com SCHEDULE ,' 7DVN1DPH 'XUDWLRQ 6WDUW )LQLVK 3UHGHFHVVRUV /HIW7XUQ/DQHV3URMHFW GD\V 7XH
7XH
&LW\,VVXHV173 GD\V 7XH
7XH
%DFNJURXQG5HVHDUFK GD\V 7XH
0RQ 2EWDLQ+LVWRULFDO'RFXPHQWVDQG5HYLHZ GD\V 7XH 0RQ
5HVHDUFK%RXQGDU\ GD\V 7XH
:HG 3UHSDUH8WLOLW\$/HWWHUV GD\V 7XH 7KX 3HUIRUP7RSRJUDSKLF6XUYH\ GD\V 7XH 0RQ &RQVWUXFWLRQ'RFXPHQWVDQG(VWLPDWHV GD\V 7XH 0RQ
*HRPHWULFDQG&RQVWUDLQWV0HPR (VWLPDWH GD\V 7XH 0RQ
&LW\5HYLHZDQG)LQDO6FRSH6HOHFWLRQ GD\V 7XH
0RQ
6XEPLWWDO GD\V 7XH
0RQ
3UHSDUHIRU6XEPLWWDO GD\V 7XH
0RQ
3XEOLF2XWUHDFK0HHWLQJ GD\V 0RQ 0RQ $JHQF\3ODQ&KHFN GD\V 7XH 0RQ 6XEPLWWDO GD\V 7XH
0RQ
3UHSDUHIRU
6XEPLWWDO GD\V 7XH
0RQ
$JHQF\3ODQ&KHFN GD\V 7XH 0RQ DQG)LQDO6XEPLWWDOV GD\V 7XH 0RQ
3UHSDUHIRU6XEPLWWDO GD\V 7XH 0RQ 3XEOLF2XWUHDFK0HHWLQJ GD\V 0RQ 0RQ $JHQF\)LQDO5HYLHZDQG$SSURYDO GD\V 7XH 0RQ $GYHUWLVHDQG&RQWUDFW$ZDUG GD\V 7XH 7XH
)LQDO3ODQ$SSURYDOV %LG3DFNDJH3UHS GD\V 7XH 0RQ $GYHUWLVH3URMHFWWR%LGGHUV GD\V 7XH 0RQ %LG2SHQLQJ GD\V 0RQ 0RQ )LQDO6WDII5HSRUW GD\V 7XH 0RQ
&LW\&RXQFLO$XWKRUL]DWLRQ GD\V 7XH 7XH %LRORJ\3UH&RQVWUXFWLRQ6XUYH\ GD\V :HG 7XH
$ZDUG&RQWUDFW GD\V :HG
7XH ,VVXH1RWLFHWR3URFHHG GD\V :HG 7XH
&RQVWUXFWLRQ GD\V :HG 7XH
0D\ -XQ -XO $XJ6HS 2FW 1RY'HF -DQ )HE 0DU $SU 0D\ -XQ -XO $XJ6HS 2FW 1RY'HF -DQ )HE 0DU $SU 0D\ -XQ -
7DVN&ULWLFDO7DVN0LOHVWRQH6XPPDU\5ROOHG8S7DVN5ROOHG8S&ULWLFDO7DVN 5ROOHG8S0LOHVWRQH5ROOHG8S3URJUHVV6SOLW([WHUQDO7DVNV3URMHFW6XPPDU\*URXS%\6XPPDU\ ,QDFWLYH7DVN,QDFWLYH0LOHVWRQH,QDFWLYH6XPPDU\0DQXDO7DVN'XUDWLRQRQO\0DQXDO6XPPDU\5ROOXS 0DQXDO6XPPDU\6WDUWRQO\)LQLVKRQO\3URJUHVV'HDGOLQH0DQXDO3URJUHVV 352-(&76&+('8/(
&,7<2)672&.721/()7785132&.(76,03529(0(176
&,7<2)672&.721&$/,)251,$
3URMHFW
/HIW7XUQ/DQHV'DWH
7KXdŚƵϰͬϮϭͬϮϮ
EXHIBIT C Page 18 of 37 ATACHMENT B 1000
The City of Stockton is now using www.PINSAdvantage.com to track Insurance Certificates and all related documents.
The PINS system starts with The City of Stockton. A Stockton User logs into PINS and emails a request for proof of insurance to the Vendor/Contractor. The Vendor/Contractor forwards the request email to their Insurance Agent(s). The Insurance Agent(s) logs into www.PINSAdvantage.com and completes the insurance certificate online.
www.pinsadvantage.com
+ 1 626 844 1838
WHAT IS THE PROCESS?
Note: Vendors will receive the insurance request email from: [email protected] Thank you for your compliance!
01 02
03 04
The Vendor/
Contractor forwards
the email to their
insurance agent(s).
PINS notifies
The City of Stockton
that documents have
been submitted and
automatically checks
for compliance.
Agent(s) log into
PINSAdvantage.com
and complete
the insurance
certificate online
A Stockton User
logs into PINS and
emails a request for
insurance to the
Vendor/Contractor
EXHIBIT D Page 19 of 37 ATACHMENT B 1001
REV 2017_09_01
https://stocktonca-my.sharepoint.com/personal/chyerle_leach_stocktonca_gov/Documents/Traffic/TRAFFIC - Main/Zulema/WT22046/Exhibit_02_Insurance_for_WT22046.docx NOTE: The City of Stockton is now using the online insurance program PINS Advantage. Once you have been awarded a contract you will receive an email from the City’s online insurance program requesting you to forward the email to your insurance provider(s). Please see attached flyer regarding PINS Advantage.
Insurance Requirements for Professional Services
Contractor shall procure and maintain for the duration of the contract insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, its agents, representatives, or employees.
MINIMUM SCOPE AND LIMIT OF INSURANCE
Coverage shall be at least as broad as:
1. Commercial General Liability (CGL): Insurance Services Office Form CG 00 01 covering CGL on an “occurrence” basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $2,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit.
2. Automobile Liability: Insurance Services Office Form Number CA 0001 covering, Code 1 (any auto), or if Contractor has no owned autos, Code 8 (hired) and 9 (nonowned), with limit no less than $1,000,000 per accident for bodily injury and property damage.
3. Workers’ Compensation insurance as required by the State of California, with Statutory Limits, and Employer’s Liability Insurance with limit of no less than $1,000,000 per accident for bodily injury or disease.
(Not required if Contractor provides written verification it has no employees)
4. Professional Liability (Errors and Omissions) Insurance appropriate to the Contractor’s profession, with limit no less than $2,000,000 per occurrence or claim, $2,000,000 aggregate. (If Claims-made, see below.)
It shall be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be available to the Additional Insured. Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any EXHIBIT D Page 20 of 37 ATACHMENT B 1002
REV 2017_09_01
Insurance policy or proceeds available to the named insured; whichever is greater. No representation is made that the minimum insurance requirements of this agreement are sufficient to cover the obligations of the Contractor under this agreement.
Limits of Insurance
The limits of insurance required in this agreement may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis before the City’s own insurance or self-insurance shall be called upon to protect it as a named insured.
Other Insurance Provisions
The insurance policies are to contain, or be endorsed to contain, the following provisions:
Additional Insured Status
The City of Stockton, its officers, officials, employees, and volunteers are to be covered as additional insureds on the CGL policy with respect to liability arising out of work or operations performed by or on behalf of the Contractor including materials, parts, or equipment furnished in connection with such work or operations. General liability coverage can be provided in the form of an endorsement to the Contractor’s insurance (at least as broad as ISO Form CG 20 10 11 85 or if not available, through the addition of both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 if a later edition is used). Additional insured Name of Organization shall read “City of Stockton, its officers, officials, employees, and volunteers.” Policy shall cover City of Stockton, its officers, officials, employees, and volunteers for all locations work is done under this contract.
Primary Coverage
The Additional Insured coverage under the Contractor’s policy shall be “primary and non-contributory” and will not seek contribution from the City’s insurance or selfinsurance and shall be at least as broad as CG 20 01 04 13. The City of Stockton does not accept endorsements limiting the Contractor’s insurance coverage to the sole negligence of the Named Insured.
Notice of Cancellation
Each insurance policy required above shall state that coverage shall not be canceled, except with notice to the City of Stockton.
Waiver of Subrogation
EXHIBIT D Page 21 of 37 ATACHMENT B 1003
REV 2017_09_01
Contractor hereby grants to City of Stockton a waiver of any right to subrogation which any insurer of said Contractor may acquire against the City of Stockton by virtue of the payment of any loss under such insurance. Contractor agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation, but this provision applies regardless of whether or not the City of Stockton has received a waiver of subrogation endorsement from the insurer. The Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of the City of Stockton for all work performed by the Contractor, its employees, agents and subcontractors.
Self-Insured Retentions
All Self-insured retentions must be disclosed to Risk Management for approval and shall not reduce the limits of liability. The City of Stockton may require the Contractor to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention.
The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the named insured or City of Stockton.
Acceptability of Insurers
Insurance is to be placed with insurers with a current A.M. Best’s rating of no less than A:VII, unless otherwise acceptable to the City of Stockton.
Claims Made Policies (note – applicable only to professional liability) If any of the required policies provide coverage on a claims-made basis:
1. The Retroactive Date must be shown and must be before the date of the contract or the beginning of contract work.
2. Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of the contract of work.
3. If coverage is canceled or non-renewed, and not replaced with another claimsmade policy form with a Retroactive Date prior to the contract effective date, the Contractor must purchase “extended reporting” coverage for a minimum of five (5) years after completion of contract work.
Verification of Coverage
EXHIBIT D Page 22 of 37 ATACHMENT B 1004
REV 2017_09_01
Contractor shall furnish the City of Stockton with original certificates and amendatory endorsements or copies of the applicable policy language effecting coverage required by this clause. All certificates and endorsements are to be received and approved by the City of Stockton Risk Services before work commences. However, failure to obtain the required documents prior to the work beginning shall not waive the Contractor’s obligation to provide them. The City of Stockton reserves the right to require complete, certified copies of all required insurance policies, including endorsements required by these specifications, at any time.
Contractor shall, prior to the commencement of work under this Agreement, provide the City of Stockton with a copy of its declarations page(s) and endorsement page(s) for each of the required policies.
Subcontractors
Contractors shall require and verify that all subcontractors, or other parties hired for this work, purchase and maintain coverage for indemnity and insurance requirements as least as broad as specified in this agreement to the extent they apply to the scope of the subcontractor’s work with the same certificate of insurance requirements and naming as additional insureds all parties to this contract. Contractor shall include the following language in their agreement with Subcontractors: Subcontractors hired by Contractor agree to be bound to Contractor and City in the same manner and to the same extent as Contractor is bound to City under the contract documents and provide a valid certificate of insurance and the required endorsements included in the agreement as proof of compliance prior to commencement of any work and to include this same requirement for any subcontractors they hire for this work. A copy of the owner contract document indemnity and insurance provisions will be furnished to the subcontractor upon request. Contractor shall provide proof of such compliance and verification to the City upon request.
Special Risks or Circumstances
City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances.
Certificate Holder Address
Proper address for mailing certificates, endorsements and notices shall be:
City of Stockton Attn: City Risk Services
400 E Main Street, 3rd Floor – HR
Stockton, CA 95202
EXHIBIT D Page 23 of 37 ATACHMENT B 1005
EXHIBIT E Page 24 of 37 ATACHMENT B 1006
EXHIBIT E Page 25 of 37 ATACHMENT B 1007
EXHIBIT E Page 26 of 37 ATACHMENT B 1008
EXHIBIT E Page 27 of 37 ATACHMENT B 1009
EXHIBIT E Page 28 of 37 ATACHMENT B 1010
EXHIBIT E Page 29 of 37 ATACHMENT B 1011
EXHIBIT E Page 30 of 37 ATACHMENT B 1012
EXHIBIT E Page 31 of 37 ATACHMENT B 1013
EXHIBIT E Page 32 of 37 ATACHMENT B 1014
EXHIBIT E Page 33 of 37 ATACHMENT B 1015
EXHIBIT E Page 34 of 37 ATACHMENT B 1016
EXHIBIT E Page 35 of 37 ATACHMENT B 1017
EXHIBIT E Page 36 of 37 ATACHMENT B 1018
EXHIBIT E Page 37 of 37 ATACHMENT B 1019
City of Stockton
Legislation Text
File #: 22-0689, Version: 1
ADOPT RESOLUTION TO AUTHORIZE THE SIDEWALK, CURB, AND GUTTER REPAIRS PROGRAM FY 2021-22 SB1 PROJECT
RECOMMENDATION
It is recommended that the City Council adopt a resolution to:
1. Approve Notice of Exemption No. NOE6-22 under the California Environmental Quality Act for the Sidewalk, Curb, and Gutter Repairs Program FY 2021-22 SB1, Project No. WD22004.
2. Approve the plans and specifications for the Sidewalk, Curb, and Gutter Repairs Program FY 2021-22 SB1, Project No. WD22004.
3. Award a Construction Contract in the amount of $1,265,240 to United Pavement Maintenance, Inc. of Hughson, CA, for the Sidewalk, Curb, and Gutter Repairs Program FY 2021-22 SB1, Project No. WD22004.
It is also recommended that the City Manager be authorized to take appropriate and necessary actions to carry out the purpose and intent of this resolution.
Summary
The project will remove and replace sidewalks, curbs, and gutters damaged by City-maintained tree roots at approximately 109 locations citywide (Attachments A and B) and will reduce the City's current sidewalk repair backlog. The project was included in the 2021-26 Five-Year Capital Improvement Plan (CIP).
On March 10, 2022, the City received four bids for this project. Staff recommends award of the Construction Contract to the lowest responsive bidder, United Pavement Maintenance, Inc., in the amount of $1,265,240. Staff also recommends that Council adopt a resolution approving Notice of Exemption No. NOE6-22 under the California Environmental Quality Act (CEQA) and approving the plans and specifications for the project. Construction is anticipated to begin late summer 2022 and be completed by December 2022, weather permitting.
DISCUSSION
Background
The City maintains approximately 780 centerline miles of streets, most of which contain curbs, gutters, and sidewalks. Prior to 1968, the adjacent property owner was responsible for all maintenance of the curbs, gutters, and sidewalks in accordance with the Streets and Highways City of Stockton Page 1 of 3 Printed on 9/7/2022
powered by Legistar™
1020
File #: 22-0689, Version: 1
Improvement Act of 1911. In 1968, Council revised the Stockton Municipal Code (SMC) to assume responsibility for repairs to all curbs, gutters, and sidewalks in cases where the damage is caused by City-owned or controlled trees (SMC 12.04.040).
The City regularly receives requests to repair curbs, gutters, and sidewalks. Each request is evaluated to determine whether the repair is a City responsibility. If repairs are warranted, the location is added to a database for future permanent repairs. For sidewalk locations that need immediate correction, the temporary repair is made using asphalt or concrete material to patch the displaced area to remove the tripping hazard. Permanent repairs are made as funding becomes available and are prioritized in chronological order based on the date of the original service request.
The Sidewalk, Curb, and Gutter Repairs Program FY 2021-22 SB1 project was included in the 2021- 26 Five-Year CIP. The project will remove and replace sidewalks, curbs, and gutters damaged by City-maintained tree roots at approximately 109 locations citywide (Attachments A and B). Upon completion of this project, there will be approximately 1,590 curbs, gutters, and sidewalk locations on the permanent repairs backlog list. This backlog list does not include locations where sidewalks are needed but do not currently exist. These locations are referred to as "sidewalk gaps" and are addressed when grant funding for "sidewalk gap closure" projects are available.
On July 26, 2016, Council adopted a Community Workforce and Training Agreement (CWTA). The CWTA became effective August 25, 2016, and applies to all Public Works projects over $1 million that are bid after that date. On July 16, 2019, by Motion No. 2019-07-16-1403, Council extended the CWTA term to August 25, 2024. The CWTA was applied to this project as the estimated construction cost is more than $1 million.
Present Situation
On February 17, 2022, the Sidewalk, Curb, and Gutter Repairs Program FY 2021-22 SB1, Project No. WD22004, was advertised for bids. On March 10, 2022, four bids were received with the following results:
COMPANY NAME BID AMOUNT ADJUSTED BID AMOUNT
(local preference applied)
United Pavement $1,265,240 $1,265,240
Maintenance, Inc.
(Hughson, CA)
FBD Vanguard $1,289,130 $1,289,130
Construction, Inc.
(Livermore, CA)
TNB Contractor, Inc. $1,298,570 $1,298,570
(Antioch, CA)
JJR Construction, Inc. $1,668,980 $1,668,980
(San Mateo, CA)
Engineer's Estimate $1,294,460
City of Stockton Page 2 of 3 Printed on 9/7/2022
powered by Legistar™
1021
File #: 22-0689, Version: 1
The contract will be awarded based on the lowest base bid received. The requirements of SMC section 3.68.090, Local Business Preference, apply to this project. Application of the Local Business Preference has no effect on the bid order. The Local Employment Ordinance, SMC section 3.68.095, also applies to this contract.
The bid from United Pavement Maintenance, Inc., the lowest responsive bidder, is regular in all respects and has the proper license to perform the work. Staff recommends Council approve the plans and specifications for the project and award a Construction Contract to United Pavement Maintenance, Inc. of Hughson, CA, in the amount of $1,265,240.
The project is in conformance with the City's General Plan, pursuant to California Government Code, section 65402, and is categorically exempt from the requirements of CEQA as specified under Section 15301(c) (Existing Facilities) of the CEQA Guidelines. The activities related to this project constitute a discretionary project under the City's jurisdiction and qualifies as a project that does not have a significant effect on the environment. The resolution will approve the filing of Notice of Exemption No. NOE6-22 under CEQA. Construction is anticipated to begin late summer 2022 and be completed by December 2022, weather permitting.
FINANCIAL SUMMARY
Road Maintenance and Rehabilitation Account funding in the amount of $1,450,000 was approved by Council on May 11, 2021, by Resolution No. 2021-05-11-1208, and appropriated to the Sidewalk, Curb, and Gutter Repairs Program FY 2021-22 SB1, Project No. WD22004, Account No. 4570-000- 800007-300-000-30-45-000-000. There is sufficient funding in the project to award a Construction Contract to United Pavement Maintenance, Inc. in the amount of $1,265,240.
There is no impact to the City’s General Fund or any other unrestricted fund as a result of taking the recommended actions.
Attachment A - List of Locations
Attachment B - Project Map
City of Stockton Page 3 of 3 Printed on 9/7/2022
powered by Legistar™
1022
No. Address
1 1142 N Hunter Street
2 1031 S Lincoln Street
3 1046 S Lincoln Street
4 307 S B Street
5 1950 E Sonora Street
6 9735 Treetop Drive
7 Venetian Drive & Mosaic Way
8 6137 Fillmore Avenue
9 3003 N Pershing Avenue
10 1736 Loggia Way
11 7603 Larkspur Lane
12 3227 W Creek Drive
13 446 Felton Way
14 Marsh Street & S B Street
15 1743 N Hunter Street
16 4120 Round Valley Circle
17 1605 E Washington Street
18 4302 Boulder Creek Circle
19 328 S Laurel Street
20 1409 Wilshire Avenue
21 502 Tuolumne Place
22 Carolyn Weston & John Townsend Place
23 3010 Carousel Circle
24 2061 S Pilgrim Street
25 1606 Picardy Drive
26 1238 N Center Street
27 731 Loretta Court
28 1236 W Willow Street
29 3849 Fourteen Mile Drive
30 820 and 826 N Stockton Street
31 403 W Longview Avenue
32 6336 Pacific Avenue
33 1405 E Acacia Street
Project No. WD22004
Sidewalk, Curb, and Gutter Repairs Program FY 2021‐22 SB1 Location List
ATTACHMENT A 1023
No. Address
Project No. WD22004
Sidewalk, Curb, and Gutter Repairs Program FY 2021‐22 SB1 Location List
34 2014 Angelico Circle
35 129 W Oak Street
36 2613 Otto Drive
37 101 E Mariposa Avenue
38 5472 Carrington Circle
39 27 W Adams Street
40 4217 Round Valley Circle
41 2175 Raymond Avenue
42 227 E Ellis Street
43 812 W Acacia Street
44 1526 Pinchot Street
45 3275 Angel Drive
46 545 W Flora Street
47 2902 N El Dorado Street
48 1346 E Harding Way
49 1061 W Willow Street
50 1045 W Willow Street
51 5504 Passero Way
52 4156 Five Mile Drive
53 E Acacia Street & N El Dorado Street
54 606 E Jefferson Street
55 1436 Princeton Avenue
56 2275 N Argonaut Street
57 8328 Kinross Way
58 1405 N Madison Street
59 901 Columbia Avenue
60 5310 N El Dorado Street
61 414 Berrendo Lane
62 1140 N Country Club Boulevard
63 2011 Myrtle Street
64 1512 Sycamore Avenue
65 2837 Chauncy Circle
66 523 E Anderson Street
ATTACHMENT A 1024
No. Address
Project No. WD22004
Sidewalk, Curb, and Gutter Repairs Program FY 2021‐22 SB1 Location List
67 1631 W Rose Street
68 1301 S Van Buren Street
69 1572 W Poplar Street
70 1064 Carrie Street
71 1305 S San Joaquin Street
72 1311 S San Joaquin Street
73 3011 Castellon Way
74 1106 W Downs Street
75 838 W Vine Street
76 2405 N San Joaquin Street
77 2425 N San Joaquin Street
78 19 W Noble Street
79 3116 N San Joaquin Street
80 702 Villanueva Court
81 1135 N Sutter Street
82 215 W Mayfair Avenue
83 Houston Avenue & Eighth Street
84 8402 Saratoga Way
85 W Harding Way & Buena Vista Avenue
86 1013 E Oak Street
87 3113 Sleepy Hollow Drive
88 2176 Raymond Avenue
89 Buena Vista Avenue & W Rose Street
90 618 N Grant Street
91 1048 N Baker Street
92 2333 & 2325 E Church Street
93 6833 Herndon Place
94 827 King Avenue
95 1230 S Madison Street
96 305 W Walnut Street
97 10 W Walnut Street
98 2633 Pacific Avenue
99 1910 S California Street
ATTACHMENT A 1025
No. Address
Project No. WD22004
Sidewalk, Curb, and Gutter Repairs Program FY 2021‐22 SB1 Location List
100 1912 S California Street
101 3002 Elmwood Avenue
102 1835 Venetian Drive
103 1801 Atchenson Street
104 326 Janie Court
105 1145 N Hunter Street
106 5440 Audrey Drive
107 669 Euclid Avenue
108 400 S Lincoln Street
109 674 Regent N Street
ATTACHMENT A 1026
HAMMER LN HAMMER LN
BEN HOLT DR
EL DORADO
ST
WILSON WY
MARCH LN
MARCH LN
WATERLOO RD
FREMONT ST
MARIPOSA
RD
AIRPORT WY
DR MLK JR BL
MAIN ST
EIGHT MILE RD
DAVIS RD
THORNTON RD
LOWER SACTO
RD
WEST LN
PARK ST
PACIFIC AV
GATEWAY
ALPINE RD
CHEROKEE RD
ROBERTS RD
EIGHTH ST
MORADA LN
PACIFIC AV
PERSHING AV
ALPINE AV
WEST LN
HARDING WY
EL DORADO ST
CALIF ST
CENTER ST
HOLMAN RD
TRINIT Y PK
LOWER SACT
CHARTER WY
!(
!(
!(!(
!(!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!( !(
!(
!(
!( !(!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!( !( !(
!(
!(
!(
!(
!( !(
!(
!(
!(
!(
!(
!(
!(
!(
!(
!(
9 109
8 7
6 5
4 3
2 1
99 98
96 97
95 94
93 92
91 89 90
88 87
86 85
84 83
82 81
80 79
78 77
76 75
74 73
72 70
69 67
66 65
64 63
62 61
60 59
58 57
56 55
54 53
52 51
49 50
48 47
45 44
42 41
40 39
38 35
34 33
32 31
29 28
27 26
25 24
23 22
21 20
17 19
16 14
13 12
11 10
108
107
106
104
103
102
101
100
71 68
46 43
37 36
30 18
15 105
0 0.375 0.75 1.5 2.25 3
µ
Miles
LEGEND
!( Sidewalk Repair Locations, Project No. WD22004
Parks
Public Schools
Sidewalk, Curb, and Gutter Repairs Program FY21-22 SB1
Project No. WD22004
CITY OF STOCKTON
DEPARTMENT OF PUBLIC WORKS
ATTACHMENT B
1027
Resolution No.
STOCKTON CITY COUNCIL
RESOLUTION APPROVING THE NOTICE OF EXEMPTION NO. NOE6-22,
APPROVING THE PLANS AND SPECIFICATIONS, AND AWARDING A
CONSTRUCTION CONTRACT FOR THE SIDEWALK, CURB, AND GUTTER REPAIRS PROGRAM FY 2021-22 SB1, PROJECT NO. WD22004
On March 10, 2022, the City Clerk of the City of Stockton opened, examined, and publicly declared the sealed proposals or bids offered for the Sidewalk, Curb, and Gutter Repairs Program FY 2021-22 SB1, Project No. WD22004; and The project will remove and replace sidewalks, curbs, and gutters damaged by City-maintained tree roots at approximately 109 locations citywide and will reduce the City’s current sidewalk repair backlog; and
United Pavement Maintenance, Inc. is the lowest responsive bidder, in the amount of $1,265,240, and its bid is regular in all respects; and The project is categorically exempt from the requirements of the California Environmental Quality Act (CEQA) as specified under section 15301(c) (Existing Facilities) of the CEQA Guidelines, because this is a discretionary project under the City’s jurisdiction and qualifies as a project which has been determined to not have a significant effect on the environment; now, therefore,
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF STOCKTON, AS FOLLOWS:
1. The City Council approves the filing of Notice of Exemption No. NOE6-22 under the CEQA for the Sidewalk, Curb, and Gutter Repairs Program FY 2021-22 SB1, Project No. WD22004, a copy of which is attached as Exhibit 1 and incorporated by this reference.
2. The City Council approves the plans and specifications for the Sidewalk, Curb, and Gutter Repairs Program FY 2021-22 SB1, Project No. WD22004.
3. The City Council awards a Construction Contract between the City of Stockton and United Pavement Maintenance, Inc. in the amount of $1,265,240, and the City Manager is authorized and directed to execute same, a copy of which is attached as Exhibit 2 and incorporated by this reference.
//
//
//
//
//
1028
4. The City Manager is hereby authorized to take whatever actions are necessary and appropriate to carry out the purpose and intent of this Resolution.
PASSED, APPROVED, and ADOPTED September 13, 2022 .
KEVIN J. LINCOLN II
Mayor of the City of Stockton
ATTEST:
ELIZA R. GARZA, CMC
City Clerk of the City of Stockton
1029
EXHIBIT 1 1030
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22004 (Updated 12/31/20)
CONSTRUCTION CONTRACT
This contract is made and entered into on _____________, by and between UNITED PAVEMENT MAINTENANCE, INC., a STATE OF CALIFORNIA CORPORATION, with a business address at 7017 HUGHSON AVE, HUGHSON, CA 95326, hereinafter called "CONTRACTOR," and CITY OF STOCKTON, a municipal corporation, hereinafter called "CITY."
W I T N E S S E T H:
WHEREAS, plans and specifications for the construction of SIDEWALK, CURB, AND GUTTER REPAIRS PROGRAM FY 2021-22 SB1 (PROJECT NO.
WD22004), hereinafter called “PROJECT,” were regularly adopted by Council Resolution No. __________________, on _________________; and WHEREAS the contract for said work was regularly awarded to CONTRACTOR, by Council Resolution No. __________________, on ________________.
NOW, THEREFORE, in consideration of the promises and of the mutual covenants herein contained, the parties hereto expressly agree as follows:
CONTRACTOR agrees:
1. SCOPE OF SERVICES. To do the work and furnish all the labor, materials, tools, equipment, and insurance required for the construction of PROJECT in accordance with the plans and specifications adopted on _____________, by Council Resolution No. __________________ . The "contract documents," which include the bid documents, project plans, specifications, all letters of clarification, and the City of Stockton Standard Specifications and Plans, are incorporated into and made a part of this contract by this reference to the same extent as if fully set forth.
2. COMPENSATION. To do and perform the work contemplated hereby in a good and workmanlike manner and to furnish all labor, materials, tools, and equipment necessary therefore at the prices specified in Exhibit A, attached hereto and by reference made a part hereof, under the direction of and to the complete satisfaction of the Director of Public Works of the City of Stockton. Total compensation for services and reimbursement for costs shall not exceed $1,265,240.00, or as otherwise mutually agreed to in a Contract Change Order.
3. INSURANCE. CONTRACTOR shall not commence any work before obtaining, and shall maintain in force at all times during the duration and performance of this contract, the policies of insurance specified in Exhibit B, which is attached to this contract and incorporated by this reference, and as provided in the “contract documents” including Section 7-1.06 of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27, effective September 27, 2016.
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22004 (Updated 12/31/20)
It shall be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be available to the Additional Insured.
Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any insurance policy or proceeds available to the named Insured; whichever is greater.
The Additional Insured coverage under the CONTRACTOR’s policy shall be “primary and non-contributory” and will not seek contribution from the City of Stockton’s insurance or self-insurance and shall be at least as broad as ISO CG 20 01 04 13.
The limits of insurance required in this agreement may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis for the benefit of the City of Stockton (if agreed to in a written contract or agreement) before the City of Stockton’s own insurance or selfinsurance shall be called upon to protect it as a named insured.
All self-insured retentions (SIR) must be disclosed to the CITY’s Risk Management for approval and shall not reduce the limits of liability. Payment Bond in the amount of the self-insured retention (SIR) may be required.
Policies containing any self-insured retention (SIR) provision shall provide or be endorsed to provide that the SIR may be satisfied by either the named insured or the CITY.
The CITY reserves the right to obtain a full certified copy of any insurance policy and endorsements.
Failure to exercise this right shall not constitute a waiver of right to exercise later.
CONTRACTOR shall maintain insurance as required by this contract to the fullest amount allowed by law and shall maintain insurance for a minimum of five years following the completion of this project. In the event contractor fails to obtain or maintain completed operations coverage as required by this agreement, the City at its sole discretion may purchase the coverage required and the cost will be paid by contractor.
CONTRACTOR agrees to include with all Subcontractors in their subcontract the same requirements and provisions of this agreement including the indemnity and insurance requirements to the extent they apply to the scope of the Subcontractor’s work.
Subcontractors hired by CONTRACTOR agree to be bound to CONTRACTOR and the CITY in the same manner and to the same extent as CONTRACTOR is bound to the CITY under the Contract Documents. Subcontractor further agrees to include these same
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22004 (Updated 12/31/20)
provisions with any Sub-subcontractor. A copy of the CITY Contract Document Indemnity and Insurance provisions will be furnished to the Subcontractor upon request. The General CONTRACTOR shall require all sub-contractors to provide a valid certificate of insurance and the required endorsements included in the agreement prior to commencement of any work and contractor will provide proof of compliance to the City.
4. INDEMNITY AND HOLD HARMLESS. With the exception that this section shall in no event be construed to require indemnification by Contractor to a greater extent than permitted under the public policy of the State of California, Contractor shall indemnify, protect, defend with counsel approved by City and at Contractor’s sole cost and expense, and hold harmless City, its Mayor, Council, officials, representatives, agents, employees, and volunteers from and against any and all claims, causes of action, liabilities, judgments, awards, losses, liens, claims, stop notices, damages, expenses, and costs (including without limitation attorneys’ fees, expert and consultant fees, and other expenses of litigation) of every nature, including, but not limited to, death or injury to persons, or damage to property, which arise out of or are in any way connected with the work performed, materials furnished, or services provided under this Agreement, or from any violation of any federal, State, or municipal law or ordinance, or City Policy, by Contractor or Contractor’s officers, agents, employees, volunteers or subcontractors.
Contractor shall not be obligated to indemnify or defend City for claims finally determined by a court of law or arbitrator to arise from the active negligence or willful misconduct of the City. It is the intent of the Parties that this indemnity obligation is at least as broad as is permitted under California law. To the extent California Civil Code sections 2782, et seq., limit the defense or indemnity obligations of Contractor to City, the intent hereunder is to provide the maximum defense and indemnity obligations allowed by Contractor under the law. The indemnity set forth in this section shall not be limited by insurance requirements or by any other provision of this Agreement.
With exception that this section shall in no event be construed to require indemnification, including the duty to defend, by Contractor to a greater extent than permitted under the public policy of the State of California, the parties agree that Contractor’s duty to defend City is immediate and arises upon the filing of any claim against the City for damages which arise out of or are in any way connected with the work performed, materials furnished, or services provided under this Agreement by Contractor or Contractor’s officers, agents, employees, volunteers or subcontractors. Contractor’s duties and obligations to defend the City shall apply regardless of whether or not the issue of the City’s liability, breach of this Agreement, or other obligation or fault has been determined.
Contractor shall be immediately obligated to pay for City’s defense costs of the claim, including, but not limited to, court costs, attorney’s fees and costs, expert consultant and witness fees and costs, other witness fees, document reproduction costs, arbitration fees, and, if after final judgment an appeal is pursued, all of such costs for the appeal.
At the conclusion of the claim, if there is any determination or finding of sole active negligence or willful misconduct on the part of the City, City will then reimburse Contractor for amounts paid in excess of Contractor’s proportionate share of
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22004 (Updated 12/31/20)
responsibility for the damages within 30 days after Contractor provides City with copies of all bills and expenses incurred in the defense of the claim(s). It is agreed between the parties that this reimbursement provision assures Contractor is not obligated to defend or indemnify City in an amount greater than provided for under California law, including, without limitation, California Civil Code sections 2782, 2782.6, and 2782.8.
With the exception that this section shall in no event be construed to require indemnification by Contractor to a greater extent than permitted under the public policy of the State of California, and in addition to the other indemnity obligations in this Agreement, Contractor shall indemnify, defend, and hold harmless City, its Mayor, Council, officials, representatives, agents, employees, and volunteers from and against all claims, losses, expenses, and costs including, but not limited to, attorneys’ fees, arising out of any claim brought against the City by an employee, office, agent, or volunteer of Contractor, regardless of whether such claim may be covered by any applicable workers compensation insurance. Contractor’s indemnification obligation is not limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for the Contractor under workers’ compensation acts, disability acts, or other employee benefit acts.
The City’s acceptance of the insurance certificates required under this Agreement does not relieve the CONTRACTOR from its obligation under this paragraph. The indemnification obligations of this section shall survive the termination of this agreement.
Any exceptions to this language may result in a proposal being deemed non-responsive.
CONTRACTOR/Subcontractor's responsibility for such defense and indemnity obligations shall survive the termination or completion of this agreement for the full period of time allowed by law.
The defense and indemnification obligations of this agreement are undertaken in addition to, and shall not in any way be limited by, the insurance obligations contained in this agreement. If any section, subsection, sentence, clause or phrase of this indemnification is for any reason held to be invalid or unconstitutional, such decision shall not affect the validity of the remaining portions of this indemnification.
5. STANDARD PLANS AND SPECIFICATIONS. The performance of said work and the furnishing of said materials shall be executed in accordance with Section 8-
1.04B of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27-1213, effective September 27, 2016, and the provisions of the issued project specifications.
The Director of Public Works will furnish CONTRACTOR a weekly statement showing the number of days charged to the contract for the preceding week, the number of days specified for completion of the contract, and the number of days remaining to complete the contract. CONTRACTOR will be allowed one (1) week in which to file a written protest
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22004 (Updated 12/31/20)
setting forth in what respects said weekly statement is incorrect, otherwise, the statement shall be deemed to have been accepted by CONTRACTOR as correct.
6. WORKING DAYS. This work shall be diligently prosecuted to completion before the expiration of 90 WORKING DAYS beginning on the tenth calendar day after the date shown on the Notice to Proceed. It is agreed by the parties to the contract that in case all the work called for under the contract in all parts and requirements, is not finished or completed within the number of days as set forth, damage will be sustained by the CITY, and that it is and will be impracticable and extremely difficult to ascertain the actual damage which CITY will sustain in the event of and by reason of such delay; and it is therefore agreed that CONTRACTOR will pay to CITY the sum of TWO THOUSAND TWO HUNDRED AND NO/100 DOLLARS ($2,200) per day for each and every calendar day's delay in finishing the work in excess of the number of days prescribed; and CONTRACTOR agrees to pay said liquidated damages as herein provided, and in case the same are not paid, agrees that CITY, may deduct the amount thereof from any monies due or that may become due CONTRACTOR under the contract.
It is further agreed that in case the work called for under the contract is not finished and completed in all parts and requirements within the number of days as specified, the CITY shall have the right to increase the number of days or not, as may seem best to serve the interest of CITY, and if the CITY decides to increase the said number of days, the CITY shall further have the right to charge to CONTRACTOR, CONTRACTOR's heirs, assigns or sureties, and to deduct from the final payment for the work, all or any part, as may be deemed proper, the liquidated damages as specified or the actual cost of engineering, inspection, superintendence, and other overhead expenses which are directly chargeable to the contract, and which accrue during the period of such extension, whichever is greater, except the cost of final surveys and preparation of final estimate shall not be included in such charges.
A working day shall not include, nor shall CONTRACTOR be assessed with liquidated damages nor the additional cost of engineering and inspection during any delay beyond the time named for the completion of the work caused by acts of God or of the public enemy, acts of CITY, fire, floods, epidemics, quarantine restrictions, strikes, and freight embargoes and subject to approval by the Director of Public Works, inability to get materials ordered by CONTRACTOR or subcontractor due to such causes provided that CONTRACTOR shall notify the Director of Public Works in writing of the causes of delay within five (5) working days from the beginning of any such delay, and the Director shall ascertain the facts and the extent of the delay, and Director's findings of the facts thereon shall be final and conclusive.
If CONTRACTOR is delayed by reason of alterations made in these specifications, or by any act of the Director of Public Works or of the CITY, not contemplated by the contract, the time of completion shall be extended proportionately and CONTRACTOR shall be relieved during the period of such extension of any claim for liquidated damages,
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22004 (Updated 12/31/20)
engineering or inspection charges or other penalties. CONTRACTOR shall have no claim for any other compensation for any such delay.
7. CONFORMANCE TO APPLICABLE LAWS. Contractor shall comply with all applicable Federal, State, and Municipal laws, rules, and ordinances. Contractor shall not discriminate in the employment of persons or in the provision of services under this Contract on the basis of any legally protected classification, including race, color, national origin, ancestry, sex or religion of such person.
a. TITLE VI
Title VI of the Civil Rights Act of 1964 requires that “no person in the United States shall, on the grounds of race, color, or national origin, be excluded from participation in, be denied the benefits of, or be subjected to discrimination under any program or activity receiving federal financial assistance.” (42 USC Section 2000d)
http://www.dol.gov/oasam/regs/statutes/titlevi.htm.
The City of Stockton requires compliance with the requirements of Title VI in all of its programs and activities regardless of funding source. b. DISCRIMINATION AND HARASSMENT POLICY
The City of Stockton has a Discrimination and Harassment Policy (Exhibit C). The purpose of this policy is to reaffirm the CITY’s commitment to demonstrating respect for all individuals by strictly prohibiting discrimination and harassment, including sexual harassment in the workplace, to define the types of behavior and conduct prohibited by this policy, and to set forth a procedure for reporting, investigating, and resolving complaints of discrimination and harassment in the workplace.
c. LABOR STANDARDS PROVISIONS/CALIFORNIA LABOR CODE
The bidder shall understand that conditions set forth in Chapter 1, Part 7, Division 2 of the California Labor Code shall be considered part of the contract agreement.
https://leginfo.legislature.ca.gov/faces/codes_displayText.xhtml?lawCode= LAB&division=2.&title=&part=7.&chapter=1.&article=2.
d. PREVAILING WAGE
CONTRACTOR and any subcontractor shall pay each employee engaged in the trade or occupation not less than the prevailing hourly wage rate. In accordance with the provisions of Section 1770 of the Labor Code, the
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22004 (Updated 12/31/20)
Director of Department of Industrial Relations of the State of California has determined the general prevailing wage and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for in Section 1773.1, apprenticeship or other training programs authorized by Section 3093 and similar purposes applicable to the work to be done. CONTRACTOR performing the work under this contract shall obtain a copy of the wage rate determination and shall distribute copies to each subcontractor. As the wage determination for each craft reflects an expiration date, it shall be the prime CONTRACTOR and each subcontractor's responsibility to insure that the prevailing wage rates of concern is current and paid to the employee.
i. The CONTRACTOR performing the work shall be responsible for obtaining a copy of the State wage rate determination. State wage rates may be obtained at
http://www.dir.ca.gov/OPRL/pwd/Determinations/Northern/Northern.pd f. The CONTRACTOR shall be responsible for posting said wage rates at a prominent location at the work site and shall maintain same in a good readable condition for the duration of the work.
ii. Should the CONTRACTOR choose to work on a Saturday, Sunday or on a holiday recognized by the Labor Unions, the CONTRACTOR shall reimburse the CITY the actual cost of engineering, inspection, superintendence, and or other overhead expenses which are directly chargeable to the contract. Should such work be undertaken at the request of the CITY, reimbursement will not be required. To conform strictly with the provisions of Division 2, Part 7, Chapter 1, Article 2, of the Labor Code of the State of California. To forfeit as a penalty to CITY the sum of TWENTY-FIVE AND NO/100 DOLLARS ($25.00) for each laborer, worker, or mechanic employed by CONTRACTOR, or by any subcontractor under CONTRACTOR, in the execution of this contract, for each calendar day during which any laborer, worker, or mechanic is required or permitted to work more than eight (8) hours and who is not paid the general prevailing rate of per diem wages for holiday and overtime work in violation of the provisions of Sections 1770 to 1781 of the Labor Code of the State of California. That all sums forfeited under the provisions of the foregoing sections shall be deducted from the payments to be made under the terms of this contract.
iii. The CONTRACTOR to whom the contract is awarded shall insure that the prime and each subcontractor will in accordance with Section 1776 of the Labor Code, maintain certified payroll records. A copy of said records shall be provided with each invoice to the Public Works
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22004 (Updated 12/31/20)
Department, Attention Contract Compliance Officer. It shall be the CONTRACTOR’S responsibility to obtain copies of the current prevailing wage rate determination for all subcontractors. Additionally, certified payroll records must be uploaded to the DIR website as required by labor code.
iv. The CONTRACTOR shall comply with the provisions established in Section 1777.5 of the Labor Code concerning the 1) certified approval by local joint apprenticeship committees for the employment and training of apprentices, and 2) contribution of funds to administer and conduct apprenticeship programs, if applicable to the job. e. LOCAL EMPLOYMENT ORDINANCE
Pursuant to Stockton Municipal Code Section 3.68.095 the CONTRACTOR and all subcontractors shall make a good faith effort to employ at least 50 percent of the workforce on this project from local residents, as measured by total labor work hours. Failure of any CONTRACTOR or subcontractor to comply with these requirements shall be deemed a material breach of the contract or subcontract. CONTRACTORS and subcontractors shall maintain records necessary for monitoring their compliance with section
3.68.095.
CITY agrees:
8. COMPENSATION. To pay CONTRACTOR for the work herein
contemplated in the following manner: Progress payments will be made on or about the first day of each calendar month, in such sum as shall make the aggregate of payment up to such day equal to ninety-five percent (95%) of the proportional contract price, upon the basis of the progress certificate of the Director of Public Works as to the amount of work done and the proportional amount of the contract price represented therefore; and all of the remaining part of the contract price not as aforesaid paid, shall be paid at the expiration of thirty-five (35) days from the completion of said work of construction and the certification by the Director of Public Works of such completion.
9. SECURITIES. Pursuant to Section 22300 of the Public Contract Code, CONTRACTOR will be permitted, at its request and sole expense, to substitute securities for any monies withheld by the CITY to ensure performance under the contract. Said securities will be deposited either with the CITY or with a State or federally chartered bank as escrow agent. Securities eligible for this substitution are those listed in Section 16430 of the California Government Code or bank or savings and loan certificates of deposit.
CONTRACTOR shall be the beneficial owner of any securities substituted for monies withheld and shall receive any interest thereon.
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22004 (Updated 12/31/20)
10. CHANGE ORDERS. CITY reserves the right to make such alterations, deviations, additions to or omissions from the plans and specifications, including the right to increase or decrease the quantity of any item or portion of the work, as may be deemed by the Engineer to be necessary or advisable and to require such extra work as may be determined by the Engineer to be required for the proper completion or construction of the whole work contemplated.
Any such changes will be set forth in a contract change order which will specify, in addition to the work done in connection with the change made, adjustment of contract time, if any, and the basis of compensation for such work. A contract change order will not become effective until approved by the City Manager and/or the City Council.
Processing of change orders shall be in accordance with Section 4-1.05A of the City of Stockton Standard Specifications and Plans as adopted by Council on September 27, 2016, by Resolution No. 2016-09-27-1213, effective September 27, 2016, or as otherwise amended by Council. When the compensation for an item of work is subject to adjustment under the provisions of Standard Specifications and Plans, Section 4-1.05A, CONTRACTOR shall, upon request, promptly furnish the Engineer with adequate detailed cost data for such item of work.
11. AUDITS. CITY reserves the right to periodically audit all charges made by CONTRACTOR to CITY for services under the contract. Upon request, CONTRACTOR agrees to furnish CITY, or a designated representative, with necessary information and assistance.
CONTRACTOR agrees that CITY or its delegate will have the right to review, obtain and copy all records pertaining to performance of the contract. CONTRACTOR agrees to provide CITY or its delegate with any relevant information requested and shall permit CITY or its delegate access to its premises, upon reasonable notice, during normal business hours for the purpose of interviewing employees and inspecting and copying such books, records, accounts, and other material that may be relevant to a matter under investigation for the purpose of determining compliance with this requirement.
CONTRACTOR further agrees to maintain such records for a period of three (3) years after final payment under the contract.
//
//
//
//
//
//
//
//
//
//
EXHIBIT 2 1040
EXHIBIT A Page 11 of 61 EXHIBIT 2 1041
EXHIBIT A Page 12 of 61 EXHIBIT 2 1042
EXHIBIT A Page 13 of 61 EXHIBIT 2 1043
EXHIBIT A Page 14 of 61 EXHIBIT 2 1044
EXHIBIT A Page 15 of 61 EXHIBIT 2 1045
EXHIBIT A Page 16 of 61 EXHIBIT 2 1046
EXHIBIT A Page 17 of 61 EXHIBIT 2 1047
EXHIBIT A Page 18 of 61 EXHIBIT 2 1048
EXHIBIT A Page 19 of 61 EXHIBIT 2 1049
EXHIBIT A Page 20 of 61 EXHIBIT 2 1050
EXHIBIT A Page 21 of 61 EXHIBIT 2 1051
EXHIBIT A Page 22 of 61 EXHIBIT 2 1052
EXHIBIT A Page 23 of 61 EXHIBIT 2 1053
EXHIBIT A Page 24 of 61 EXHIBIT 2 1054
EXHIBIT A Page 25 of 61 EXHIBIT 2 1055
EXHIBIT A Page 26 of 61 EXHIBIT 2 1056
EXHIBIT A Page 27 of 61 EXHIBIT 2 1057
EXHIBIT A Page 28 of 61 EXHIBIT 2 1058
EXHIBIT A Page 29 of 61 EXHIBIT 2 1059
EXHIBIT A Page 30 of 61 EXHIBIT 2 1060
EXHIBIT A Page 31 of 61 EXHIBIT 2 1061
EXHIBIT A Page 32 of 61 EXHIBIT 2 1062
EXHIBIT A Page 33 of 61 EXHIBIT 2 1063
EXHIBIT A Page 34 of 61 EXHIBIT 2 1064
EXHIBIT A Page 35 of 61 EXHIBIT 2 1065
EXHIBIT A Page 36 of 61 EXHIBIT 2 1066
EXHIBIT A Page 37 of 61 EXHIBIT 2 1067
EXHIBIT A Page 38 of 61 EXHIBIT 2 1068
NOTE: The City of Stockton is now using the online insurance program PINS Advantage. Once you have been awarded a contract you will receive an email from the City’s online insurance program requesting you to forward the email to your insurance provider(s). Please see attached flyer regarding PINS Advantage.
Exhibit B:
Insurance Requirements for Construction Contracts
Contractor shall procure and maintain for the duration of the contract,and for five (5) years thereafter , insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, their agents, representatives, employees, or subcontractors. In the event contractor fails to obtain or maintain completed operations coverage as required by this agreement, the City, at its sole discretion, may purchase the coverage required and the cost will be paid by the contractor.
MINIMUM SCOPE AND LIMIT OF INSURANCE
Coverage shall be at least as broad as:
1. Commercial General Liability (CGL): Insurance Services Office (ISO) Form CG 00 01 covering CGL on an “occurrence” basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $2,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit.
2. Automobile Liability: Insurance Services Office Form CA 0001 covering Code 1 (any auto), with limits no less than $2,000,000 per accident for bodily injury and property damage.
3. Workers’ Compensation insurance as required by the State of California, with Statutory Limits, and Employers’ Liability insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.
4. Surety Bonds as described below.
It shall be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be available to the Additional Insured. Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any Insurance policy or proceeds available to the named insured; whichever is greater. No EXHIBIT B Page 39 of 61 EXHIBIT 2 1069
representation is made that the minimum insurance requirements of this agreement are sufficient to cover the obligations of the Contractor under this agreement.
Limits of Insurance
The limits of insurance required in this agreement may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis before the City’s own insurance or self-insurance shall be called upon to protect it as a named insured.
Other Insurance Provisions
The insurance policies are to contain, or be endorsed to contain, the following provisions:
Additional Insured Status
The City of Stockton, its officers, officials, employees, and volunteers are to be covered as additional insureds on the CGL policy with respect to liability arising out of work or operations performed by or on behalf of the Contractor including materials, parts, or equipment furnished in connection with such work or operations. General liability coverage can be provided in the form of an endorsement to the Contractor’s insurance (at least as broad as ISO Form CG 20 10 11 85 or if not available, through the addition of both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 if a later edition is used). Additional insured Name of Organization shall read “City of Stockton, its officers, officials, employees, and volunteers.” Policy shall cover City of Stockton, its officers, officials, employees, and volunteers for all locations work is done under this contract.
Primary Coverage
The Additional Insured coverage under the Contractor’s policy shall be “primary and non-contributory” and will not seek contribution from the City’s insurance or selfinsurance and shall be at least as broad as CG 20 01 04 13. The City of Stockton does not accept endorsements limiting the Contractor’s insurance coverage to the sole negligence of the Named Insured.
Claims Made Policies – (Note – applicable only to professional and/or pollution liability)
If any coverage required is written on a claims-made coverage form:
1. The retroactive date must be shown, and this date must be before the execution date of the contract or the beginning of contract work.
EXHIBIT B Page 40 of 61 EXHIBIT 2 1070
2. Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of contract work.
3. If coverage is canceled or non-renewed, and not replaced with another claims-made policy form with a retroactive date prior to the contract effective, or start of work date, the Contractor must purchase extended reporting period coverage for a minimum of five (5) years after completion of contract work.
4. A copy of the claims reporting requirements must be submitted to the City of Stockton for review.
5. If the services involve lead-based paint or asbestos identification/remediation, the Contractors Pollution Liability policy shall not contain lead-based paint or asbestos exclusions. If the services involve mold identification/remediation, the Contractors Pollution Liability policy shall not contain a mold exclusion, and the definition of Pollution shall include microbial matter, including mold.
Notice of Cancellation
Each insurance policy required above shall provide that coverage shall not be canceled, except with notice to the City of Stockton.
Waiver of Subrogation
Contractor hereby grants to City of Stockton a waiver of any right to subrogation which any insurer of said Contractor may acquire against the City of Stockton by virtue of the payment of any loss under such insurance. Contractor agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation, but this provision applies regardless of whether or not the City of Stockton has received a waiver of subrogation endorsement from the insurer. The Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of the City of Stockton for all work performed by the Contractor, its employees, agents and subcontractors.
Self-Insured Retentions
All Self-insured retentions must be disclosed to Risk Management for approval and shall not reduce the limits of liability. The City of Stockton may require the Contractor to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention.
The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the named insured or City of Stockton.
EXHIBIT B Page 41 of 61 EXHIBIT 2 1071
Acceptability of Insurers
Insurance is to be placed with insurers with a current A.M. Best’s rating of no less than A:VII, unless otherwise acceptable to the City of Stockton.
Verification of Coverage
Contractor shall furnish the City of Stockton with original certificates and amendatory endorsements or copies of the applicable policy language effecting coverage required by this clause. All certificates and endorsements are to be received and approved by the City of Stockton Risk Services before work commences. However, failure to obtain the required documents prior to the work beginning shall not waive the Contractor’s obligation to provide them. The City of Stockton reserves the right to require complete, certified copies of all required insurance policies, including endorsements required by these specifications, at any time.
Contractor shall, prior to the commencement of work under this Agreement, provide the City of Stockton with a copy of its declarations page(s) and endorsement page(s) for each of the required policies.
Subcontractors
Contractors shall require and verify that all subcontractors, or other parties hired for this work, purchase and maintain coverage for indemnity and insurance requirements as least as broad as specified in this agreement to the extent they apply to the scope of the subcontractor’s work with the same certificate of insurance requirements and naming as additional insureds all parties to this contract. Contractor shall include the following language in their agreement with Subcontractors: Subcontractors hired by Contractor agree to be bound to Contractor and City in the same manner and to the same extent as Contractor is bound to City under the contract documents and provide a valid certificate of insurance and the required endorsements included in the agreement as proof of compliance prior to commencement of any work and to include this same requirement for any subcontractors they hire for this work. A copy of the owner contract document indemnity and insurance provisions will be furnished to the subcontractor upon request. Contractor shall provide proof of such compliance and verification to the City upon request.
Surety Bonds
Contractor shall provide the following Surety Bonds:
1. Bid bond
2. Performance bond
EXHIBIT B Page 42 of 61 EXHIBIT 2 1072
3. Payment bond (or Labor and Material bond)
4. Maintenance bond
The Payment Bond and the Performance Bond shall be in a sum equal to one hundred percent (100%) of the contract price. If the Performance Bond provides for a one-year warranty a separate Maintenance Bond is not necessary. If the warranty period specified in the contract is for longer than one year a Maintenance Bond equal to 10% of the contract price is required. Bonds shall be duly executed by a responsible corporate surety, authorized to issue such bonds in the State of California and secured through an authorized agent with an office in California.
Special Risks or Circumstances
City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances.
Certificate Holder Address
Proper address for mailing certificates, endorsements and notices shall be:
City of Stockton
Attn: City Risk Services
400 E Main Street, 3rd Floor – HR
Stockton, CA 95202
EXHIBIT B Page 43 of 61 EXHIBIT 2 1073
EXHIBIT C Page 44 of 61 EXHIBIT 2 1074
EXHIBIT C Page 45 of 61 EXHIBIT 2 1075
EXHIBIT C Page 46 of 61 EXHIBIT 2 1076
EXHIBIT C Page 47 of 61 EXHIBIT 2 1077
EXHIBIT C Page 48 of 61 EXHIBIT 2 1078
EXHIBIT C Page 49 of 61 EXHIBIT 2 1079
EXHIBIT C Page 50 of 61 EXHIBIT 2 1080
EXHIBIT C Page 51 of 61 EXHIBIT 2 1081
EXHIBIT C Page 52 of 61 EXHIBIT 2 1082
EXHIBIT C Page 53 of 61 EXHIBIT 2 1083
EXHIBIT C Page 54 of 61 EXHIBIT 2 1084
EXHIBIT C Page 55 of 61 EXHIBIT 2 1085
EXHIBIT C Page 56 of 61 EXHIBIT 2 1086
EXHIBIT C Page 57 of 61 EXHIBIT 2 1087
BOND FOR FAITHFUL PERFORMANCE
KNOW ALL MEN BY THESE PRESENTS:
That we, UNITED PAVEMENT MAINTENANCE, INC., a STATE OF
CALIFORNIA CORPORATION, as Principal and
, a corporation, organized and existing under the laws of the State of and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, as oblige, in the just and full sum of ONE MILLION TWO HUNDRED SIXTY-FIVE THOUSAND TWO HUNDRED FORTY DOLLARS AND 00/100 DOLLARS ($1,265,240), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to the said CITY, the said Principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.
The condition of the foregoing obligation is such that the above bounded Principal has simultaneously entered into a contract with the CITY, to do and perform the following work, to wit:
SIDEWALK, CURB, AND GUTTER REPAIRS PROGRAM FY 2021-22 SB1 (PROJECT NO. WD22004)
NOW, THEREFORE, if the above bounded Principal, CONTRACTOR, Company or
Corporation or its subcontractor, shall well and truly perform the work contracted to be done under said contract, then this obligation to be null and void; otherwise to remain in full force and effect.
No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract, or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY, and no forbearance on the part of the said CITY shall operate to relieve any Surety or Sureties from liability on this bond,
and consent by said Surety is hereby given, and the said Surety hereby waives the provisions of Sections 2819 and 2845 of the Civil Code of the State of California.
SIGNED AND SEALED on
APPROVED AS TO SURETY: By:
PRINCIPAL
SURETY
APPROVED AS TO FORM & CONTENT:
LORI M. ASUNCION
ACTING CITY ATTORNEY
By:
ATTORNEY-IN-FACT
By:
DEPUTY CITY ATTORNEY
BOND FOR LABOR AND MATERIAL
KNOW ALL MEN BY THESE PRESENTS:
That we, UNITED PAVEMENT MAINTENANCE, INC., a STATE OF
CALIFORNIA CORPORATION, as Principal and ,
corporation, organized and existing under the laws of the State of and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, and unto any and all material suppliers, persons, companies, or corporations furnishing materials, provisions, provender or other supplies used in, upon, for or about the performance of the work contemplated to be executed or performed under the contract hereinafter mentioned, and all persons, companies, or corporations renting or hiring teams, or implements of machinery, for or contributing to said work and all persons who perform work or labor upon the same, and all persons who supply both work and materials, and whose claims have not been paid by the contractor, company or corporation in the just and full sum of ONE MILLION TWO HUNDRED SIXTY-FIVE THOUSAND TWO HUNDRED FORTY DOLLARS AND 00/100 DOLLARS ($1,265,240), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to said CITY and to said persons jointly and severally, the said principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.
The condition of the foregoing obligations is such that the above bounden Principal has simultaneously entered into a contract of even date herewith, with the CITY, to do and perform the following work, to-wit:
SIDEWALK, CURB, AND GUTTER REPAIRS PROGRAM FY 2021-22 SB1 (PROJECT NO. WD22004)
NOW, THEREFORE, if the above bounden Principal, CONTRACTOR, Company or Corporation or its subcontractor, fail to pay for all materials, provisions, provender, or other supplies, or teams, used in, upon, for or about the performance of the work EXHIBIT 2 Page 60 of 61 1090
contracted to be done, or for any work or labor done thereon of any kind, the Surety on this bond will pay the same, in an amount not exceeding the sum specified in this bond, provided that any and all claims hereunder shall be filed and proceedings had in connection therewith as required by the provisions of Division 3, Part 4, Title 15, Chapter 5, Article 1 of the Civil Code of California, provided that in case suit is brought upon this bond, a reasonable attorney's fee shall be awarded by the Court to the prevailing party in said suit; said attorney's fee to be fixed as costs in said suit, and to be included in the judgment therein rendered.
No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY and no forbearance on the part of the said CITY shall operate to relieve any surety or sureties from liability on this bond, and consent to make such alterations without further notice to or consent by any such surety is hereby given, and the said sureties hereby waive the provisions of Sections 2819 and 2845 of the Civil Code of the State of California.
SIGNED AND SEALED on .
APPROVED AS TO SURETY: By:
PRINCIPAL
SURETY
APPROVED AS TO FORM & CONTENT:
LORI M. ASUNCION
ACTING CITY ATTORNEY
By:
ATTORNEY-IN-FACT
By:
DEPUTY CITY ATTORNEY
City of Stockton
Legislation Text
File #: 22-0701, Version: 1
ADOPT RESOLUTION TO AUTHORIZE THE SIDEWALK REPLACEMENT PROJECT
RECOMMENDATION
It is recommended that the City Council adopt a resolution to:
1. Approve Notice of Exemption No. NOE14-22 under the California Environmental Quality Act for the Sidewalk Replacement, Project No. WD22017.
2. Approve the plans and specifications for the Sidewalk Replacement, Project No. WD22017.
3. Award a Construction Contract in the amount of $150,040 to United Pavement Maintenance, Inc. of Hughson, CA, for the Sidewalk Replacement, Project No. WD22017.
It is also recommended that the City Manager be authorized to take appropriate and necessary actions to carry out the purpose and intent of this resolution.
Summary
The Sidewalk Replacement project will replace the existing damaged sidewalk, curb, gutter, curb ramp, and driveway near the Gospel Center Rescue Mission at 445 S. San Joaquin Street (Attachment A).
On May 19, 2022, the City received four bids for this project. Staff recommends award of the Construction Contract to the lowest responsive bidder, United Pavement Maintenance, Inc., in the amount of $150,040. Staff also recommends that Council adopt a resolution approving Notice of Exemption No. NOE14-22 under the California Environmental Quality Act (CEQA) and approving the plans and specifications for the project. Construction is anticipated to begin and be completed in fall 2022, weather permitting.
DISCUSSION
Background
By Resolution No. 2021-11-16-1501, Council allocated $9.85 million in funding for various park, tree, transportation, and facility projects citywide to benefit our community. The funding provided $240,000 allocated for sidewalk improvements along San Joaquin Street, adjacent to the Gospel Center Rescue Mission (Attachment A). Improvements include replacing damaged sidewalk, curb, gutter, curb ramp, and a driveway.
On July 26, 2016, Council adopted a Community Workforce and Training Agreement (CWTA). The City of Stockton Page 1 of 3 Printed on 9/7/2022
powered by Legistar™
1092
File #: 22-0701, Version: 1
CWTA became effective August 25, 2016, and applies to all Public Works projects over $1 million that are bid after that date. On July 16, 2019, by Motion No. 2019-07-16-1403, Council extended the CWTA term to August 25, 2024. The CWTA was not applied to this project because the estimated construction cost was less than $1 million.
Present Situation
On April 21, 2022, the Sidewalk Replacement, Project No. WD22017, was advertised for bids. On May 19, 2022, four bids were received with the following results:
COMPANY NAME BID AMOUNT ADJUSTED BID AMOUNT
(local preference applied)
United Pavement Maintenance, Inc.
(Hughson, CA) $150,040 $150,040
Bob Santana dba BGS Builders, Inc.
(Stockton, CA) $158,000 $150,100
FBD Vanguard Construction, Inc.
(Livermore, CA) $173,688 $173,688
Dirt Dynasty, Inc.
(Farmington, CA) $181,550 $181,550
Engineer’s Estimate $158,500
The requirements of Stockton Municipal Code (SMC) section 3.68.090, Local Business Preference, apply to this project. Bob Santana dba BGS Builders, Inc. is located within City limits and is entitled to a five percent bid preference. Application of the Local Business Preference has no effect on the bid order. The Local Employment Ordinance, SMC section 3.68.095, also applies to this contract.
The bid from United Pavement Maintenance, Inc., the lowest responsive bidder, is regular in all respects and has the proper license to perform the work. Staff recommends Council approve the plans and specifications for the project and award a Construction Contract to United Pavement Maintenance, Inc. of Hughson, CA, in the amount of $150,040.
The project is in conformance with the City’s General Plan, pursuant to California Government Code, section 65402, and is categorically exempt from the requirements of CEQA as specified under Section 15301(c) of the CEQA Guidelines. As a result, the project has been granted a Categorical Exemption. The activities related to this project constitute a discretionary project under the City’s jurisdiction and qualifies as a project that does not have a significant effect on the environment. The resolution will approve the filing of Notice of Exemption No. NOE14-22 under CEQA. Construction is anticipated to begin and be completed in fall 2022, weather permitting.
FINANCIAL SUMMARY
Council approved discretionary funding in the amount of $240,000 on November 16, 2021, by Resolution No. 2021-11-16-1501, and appropriated funding to the Sidewalk Replacement, Project City of Stockton Page 2 of 3 Printed on 9/7/2022
powered by Legistar™
1093
File #: 22-0701, Version: 1
No. WD22017, Account No. 4570-000-800007-300-301-30-45-000-000. There is sufficient funding to award a Construction Contract to United Pavement Maintenance, Inc. in the amount of $150,040.
There is no impact on the City’s General Fund or any other unrestricted fund as a result of taking the recommended actions.
Attachment A - Project Map
City of Stockton Page 3 of 3 Printed on 9/7/2022
powered by Legistar™
1094
Ã4
Ã4
§¨5
STOCKTON CHANNEL
MORMON SL
MORMON SLOUGH
MCLEOD
LK
FREMONT CH
DR MARTIN LUTHER KING JR BL
FLORA ST
CT
LINCOLN ST
ANDERSON ST
SIXTH ST
MINER AV COMMERCE ST
UNION ST SPRUCE
MAIN ST
FIRST ST
S U
T PRR (SPRR)
TURNPIKE RD
LINDSAY ST UPRR (SPRR) MALMWORTH
AURORA ST
MONROE ST SIXTH ST
FLORA ST SAN JOAQUIN ST CALI
FORNIA
ST
HU
NTER ST DR MARTIN LUTHER KING JR BL
ST
CT
SUT ER ST
MARKET ST
YOSEMITE
SIKH TEMPLE ST SAN JOAQUIN ST VAN BUREN ST
ACACIA ST
CHURCH ST
CHARTER WY
CENTER ST
AMERICAN ST
CENTER
ST HARRISON ST HOWARD ST KOLHER ST
OAK ST
GRANT ST
COMMERCE ST
CALIFORNIA ST PERALTA AV MADISON ST
FIFTH ST
THIRD ST
SUTTER ST
LAFAYETTE ST
STOCKTON
AURORA
ST
ST
POPLAR ST
MAIN ST
SIXTH ST
LAFAYETTE ST
CLAY ST
MONROE ST
CT
EL DORADO ST EL DORADO ST
FIFTH ST
THIRD ST
SAN JOAQUIN ST
NAVY DR
SIER A NEVADA
ST
OAK ST
ARGONAUT ST
JEFFERSON ST HERMAN
AMERICAN ST SYLVAN
SECOND ST
ACACIA ST
MADISON ST
CHANNEL ST
LINCOLN ST
BN&SF RR
ARGONAUT
CLAY ST MADISON ST
THOUSAND
ST
CALIFORNIA ST STANISLAUS ST
FOURTH ST
HUNTER ST AM
ERICAN ST
ST
VAN BUREN ST
HYDE
CHURCH ST
SONORA
SUTTER ST
FIFTH ST
SAN JOSE
LINCOLN ST
WORTH ST
ACACIA ST
SCOTTS AV
COMMERCE ST
THIRD ST
JEFFERSON ST
PARK ST
LINDSAY ST
AMERICAN ST CT
HARRISON ST MONROE ST
FREMONT ST ARGONAUT ST
IRENE ST
CHURCH ST
GUTING DR
FIFTH ST
ASPEN
AIRPORT
WY
BN&SF RR
WEBER AV
EIGHTH ST
EL
DORADO ST
PILGRIM
GREN
HUNTER ST BAKER
CENTER ST
ST
SONORA
STOCKTON ST
SANCHEZ
ANDERSON GRANT ST
BAKER
ST STOCKTON ST
PILGRIM ST STANISLAUS ST
PARK ST
AURORA
ST
HUNTER ST
SONORA
SUTTER ST MARKET ST
LINDSAY ST
TAYLOR ST
OAKS
ANDERSON
SAN JOAQUIN ST
SECOND ST
JACKSON ST
MADISON ST
STANISLAUS ST CLOYNE
HAZELTON AV MERLOT
WASHINGTON ST
SEVENTH ST
AURORA ST
JACKSON ST
WASHINGTON ST UPRR
FOURTH ST
VAN BUREN ST CENTER ST HOWARD ST
PROJECT LOCATION
0 0.15 0.3 0.45 0.6 0.075
µ
Miles
LEGEND
!( Project Location
Parks
Public Schools
Sidewalk Replacement Project
Project No. WD22017
CITY OF STOCKTON
DEPARTMENT OF PUBLIC WORKS
EIGHT MILE RD EIGHT MILE RD
ALPINE RD ROBERTS RD
HOWARD RD MAIN ST PERSHING AV
EL DORADO ST EIGHT MILE RD
DAV SI RD THORNTON RD
EL DORADO ST WEST LN
PAC IFIC AV MARCH LN
ALPINE AV CHEROKE RD
AIRPORT WY CENTER ST
FRENCH CAMP RD MAIN ST AIRPORT WY CHEROKEE RD
ALPINE RD
ROBERTS RD
HOWARD RD
LOWER SACRAM ENTO R D W ILSO N W Y
PAC IFIC AV DR MLK JR BL MARIPO SA RD
HOLMA N RD
HOLMAN RD
TRINITY PK WEST LN MORADA LN
THORNTO N RD
HAMMER LN
HAMMER LN PER SHING AV
BE NJ.HOLT DR MAR CH LN
HARDING WY WEST LN WATER LO O R D WILSON WY NAVY DR
EIGHTH ST
FREN CH CA M P RD
AIRPORT WY
FREMONT ST SPERRY RD
ARCH AIRPORT RDMA RCH LN MATHEWS RD
EL DORADO ST CHARTER WY
ATTACHMENT A 1095
Resolution No.
STOCKTON CITY COUNCIL
RESOLUTION APPROVING THE NOTICE OF EXEMPTION NO. NOE14-22,
APPROVING THE PLANS AND SPECIFICATIONS, AND AWARDING A
CONSTRUCTION CONTRACT FOR THE SIDEWALK REPLACEMENT, PROJECT NO.
WD22017
On May 19, 2022, the City Clerk of the City of Stockton opened, examined, and publicly declared the sealed proposals or bids offered for the Sidewalk Replacement, Project No. WD22017; and
The project will replace the existing damaged sidewalk, curb, gutter, curb ramp, and driveway near the Gospel Center Rescue Mission at 445 S. San Joaquin Street, Stockton, CA; and
United Pavement Maintenance, Inc. is the lowest responsive bidder, in the amount of $150,040, and its bid is regular in all respects; and The project is categorically exempt from the requirements of the California Environmental Quality Act (CEQA) as specified under section 15301(c) of the CEQA Guidelines, because this is a discretionary project under the City’s jurisdiction and qualifies as a project which has been determined to not have a significant effect on the environment; now, therefore,
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF STOCKTON, AS FOLLOWS:
1. The City Council approves the filing of Notice of Exemption No. NOE14-22 under the CEQA for the Sidewalk Replacement, Project No. WD22017, a copy of which is attached as Exhibit 1 and incorporated by this reference.
2. The City Council approves the plans and specifications for the Sidewalk Replacement, Project No. WD22017.
3. The City Council awards a Construction Contract between the City of Stockton and United Pavement Maintenance, Inc., in the amount of $150,040, and the City Manager is authorized and directed to execute same, a copy of which is attached as Exhibit 2 and incorporated by this reference.
//
//
//
1096
4. The City Manager is hereby authorized to take whatever actions are appropriate and necessary to carry out the purpose and intent of this Resolution.
PASSED, APPROVED, and ADOPTED September 13, 2022 .
________________________
KEVIN J. LINCOLN II
Mayor of the City of Stockton
ATTEST:
__________________________
ELIZA R. GARZA, CMC
City Clerk of the City of Stockton
1097
EXHIBIT 1 1098
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22017 (Updated 12/31/20)
CONSTRUCTION CONTRACT
This contract is made and entered into on _____________, by and between UNITED PAVEMENT MAINTENANCE, INC., a STATE OF CALIFORNIA CORPORATION, with a business address at 7017 HUGHSON AVE, HUGHSON CA 95326, hereinafter called "CONTRACTOR," and CITY OF STOCKTON, a municipal corporation, hereinafter called "CITY."
W I T N E S S E T H:
WHEREAS, plans and specifications for the construction of SIDEWALK REPLACEMENT (PROJECT NO. WD22017), hereinafter called “PROJECT,” were regularly adopted by Council Resolution No. __________________, on _________________; and
WHEREAS, the contract for said work was regularly awarded to CONTRACTOR, by Council Resolution No. __________________, on ________________.
NOW, THEREFORE, in consideration of the promises and of the mutual covenants herein contained, the parties hereto expressly agree as follows:
CONTRACTOR agrees:
1. SCOPE OF SERVICES. To do the work and furnish all the labor, materials, tools, equipment, and insurance required for the construction of PROJECT in accordance with the plans and specifications adopted on _____________, by - Council Resolution No. __________________ . The "contract documents," which include the bid documents, project plans, specifications, all letters of clarification, and the City of Stockton Standard Specifications and Plans, are incorporated into and made a part of this contract by this reference to the same extent as if fully set forth.
2. COMPENSATION. To do and perform the work contemplated hereby in a good and workmanlike manner and to furnish all labor, materials, tools, and equipment necessary therefore at the prices specified in Exhibit A, attached hereto and by reference made a part hereof, under the direction of and to the complete satisfaction of the Director of Public Works of the City of Stockton. Total compensation for services and reimbursement for costs shall not exceed 150,040.00, or as otherwise mutually agreed to in a Contract Change Order.
3. INSURANCE. CONTRACTOR shall not commence any work before obtaining, and shall maintain in force at all times during the duration and performance of this contract, the policies of insurance specified in Exhibit B, which is attached to this contract and incorporated by this reference, and as provided in the “contract documents” including Section 7-1.06 of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27, effective September 27, 2016.
EXHIBIT 2 Page 1 of 45 1099
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22017 (Updated 12/31/20)
It shall be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be available to the Additional Insured.
Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any insurance policy or proceeds available to the named Insured; whichever is greater.
The Additional Insured coverage under the CONTRACTOR’s policy shall be “primary and non-contributory” and will not seek contribution from the City of Stockton’s insurance or self-insurance and shall be at least as broad as ISO CG 20 01 04 13.
The limits of insurance required in this agreement may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis for the benefit of the City of Stockton (if agreed to in a written contract or agreement) before the City of Stockton’s own insurance or selfinsurance shall be called upon to protect it as a named insured.
All self-insured retentions (SIR) must be disclosed to the CITY’s Risk Management for approval and shall not reduce the limits of liability. Payment Bond in the amount of the self-insured retention (SIR) may be required.
Policies containing any self-insured retention (SIR) provision shall provide or be endorsed to provide that the SIR may be satisfied by either the named insured or the CITY.
The CITY reserves the right to obtain a full certified copy of any insurance policy and endorsements.
Failure to exercise this right shall not constitute a waiver of right to exercise later.
CONTRACTOR shall maintain insurance as required by this contract to the fullest amount allowed by law and shall maintain insurance for a minimum of five years following the completion of this project. In the event contractor fails to obtain or maintain completed operations coverage as required by this agreement, the City at its sole discretion may purchase the coverage required and the cost will be paid by contractor.
CONTRACTOR agrees to include with all Subcontractors in their subcontract the same requirements and provisions of this agreement including the indemnity and insurance requirements to the extent they apply to the scope of the Subcontractor’s work.
Subcontractors hired by CONTRACTOR agree to be bound to CONTRACTOR and the CITY in the same manner and to the same extent as CONTRACTOR is bound to the
1100
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22017 (Updated 12/31/20)
CITY under the Contract Documents. Subcontractor further agrees to include these same provisions with any Sub-subcontractor. A copy of the CITY Contract Document Indemnity and Insurance provisions will be furnished to the Subcontractor upon request. The General CONTRACTOR shall require all sub-contractors to provide a valid certificate of insurance and the required endorsements included in the agreement prior to commencement of any work and contractor will provide proof of compliance to the City.
4. INDEMNITY AND HOLD HARMLESS. With the exception that this section shall in no event be construed to require indemnification by Contractor to a greater extent than permitted under the public policy of the State of California, Contractor shall indemnify, protect, defend with counsel approved by City and at Contractor’s sole cost and expense, and hold harmless City, its Mayor, Council, officials, representatives, agents, employees, and volunteers from and against any and all claims, causes of action, liabilities, judgments, awards, losses, liens, claims, stop notices, damages, expenses, and costs (including without limitation attorneys’ fees, expert and consultant fees, and other expenses of litigation) of every nature, including, but not limited to, death or injury to persons, or damage to property, which arise out of or are in any way connected with the work performed, materials furnished, or services provided under this Agreement, or from any violation of any federal, State, or municipal law or ordinance, or City Policy, by Contractor or Contractor’s officers, agents, employees, volunteers or subcontractors.
Contractor shall not be obligated to indemnify or defend City for claims finally determined by a court of law or arbitrator to arise from the active negligence or willful misconduct of the City. It is the intent of the Parties that this indemnity obligation is at least as broad as is permitted under California law. To the extent California Civil Code sections 2782, et seq., limit the defense or indemnity obligations of Contractor to City, the intent hereunder is to provide the maximum defense and indemnity obligations allowed by Contractor under the law. The indemnity set forth in this section shall not be limited by insurance requirements or by any other provision of this Agreement.
With exception that this section shall in no event be construed to require indemnification, including the duty to defend, by Contractor to a greater extent than permitted under the public policy of the State of California, the parties agree that Contractor’s duty to defend City is immediate and arises upon the filing of any claim against the City for damages which arise out of or are in any way connected with the work performed, materials furnished, or services provided under this Agreement by Contractor or Contractor’s officers, agents, employees, volunteers or subcontractors. Contractor’s duties and obligations to defend the City shall apply regardless of whether or not the issue of the City’s liability, breach of this Agreement, or other obligation or fault has been determined.
Contractor shall be immediately obligated to pay for City’s defense costs of the claim, including, but not limited to, court costs, attorney’s fees and costs, expert consultant and witness fees and costs, other witness fees, document reproduction costs, arbitration fees, and, if after final judgment an appeal is pursued, all of such costs for the appeal.
At the conclusion of the claim, if there is any determination or finding of sole active negligence or willful misconduct on the part of the City, City will then reimburse
1101
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22017 (Updated 12/31/20)
Contractor for amounts paid in excess of Contractor’s proportionate share of responsibility for the damages within 30 days after Contractor provides City with copies of all bills and expenses incurred in the defense of the claim(s). It is agreed between the parties that this reimbursement provision assures Contractor is not obligated to defend or indemnify City in an amount greater than provided for under California law, including, without limitation, California Civil Code sections 2782, 2782.6, and 2782.8.
With the exception that this section shall in no event be construed to require indemnification by Contractor to a greater extent than permitted under the public policy of the State of California, and in addition to the other indemnity obligations in this Agreement, Contractor shall indemnify, defend, and hold harmless City, its Mayor, Council, officials, representatives, agents, employees, and volunteers from and against all claims, losses, expenses, and costs including, but not limited to, attorneys’ fees, arising out of any claim brought against the City by an employee, office, agent, or volunteer of Contractor, regardless of whether such claim may be covered by any applicable workers compensation insurance. Contractor’s indemnification obligation is not limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for the Contractor under workers’ compensation acts, disability acts, or other employee benefit acts.
The City’s acceptance of the insurance certificates required under this Agreement does not relieve the CONTRACTOR from its obligation under this paragraph. The indemnification obligations of this section shall survive the termination of this agreement.
Any exceptions to this language may result in a proposal being deemed non-responsive.
CONTRACTOR/Subcontractor's responsibility for such defense and indemnity obligations shall survive the termination or completion of this agreement for the full period of time allowed by law.
The defense and indemnification obligations of this agreement are undertaken in addition to, and shall not in any way be limited by, the insurance obligations contained in this agreement. If any section, subsection, sentence, clause or phrase of this indemnification is for any reason held to be invalid or unconstitutional, such decision shall not affect the validity of the remaining portions of this indemnification.
5. STANDARD PLANS AND SPECIFICATIONS. The performance of said work and the furnishing of said materials shall be executed in accordance with Section 8-1.04B of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27-1213, effective September 27, 2016, and the provisions of the issued project specifications.
The Director of Public Works will furnish CONTRACTOR a weekly statement showing the number of days charged to the contract for the preceding week, the number of days specified for completion of the contract, and the number of days remaining to complete the contract. CONTRACTOR will be allowed one (1) week in which to file a written protest
1102
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22017 (Updated 12/31/20)
setting forth in what respects said weekly statement is incorrect, otherwise the statement shall be deemed to have been accepted by CONTRACTOR as correct.
6. WORKING DAYS. This work shall be diligently prosecuted to completion before the expiration of 15 WORKING DAYS beginning on the tenth calendar day after the date shown on the Notice to Proceed. It is agreed by the parties to the contract that in case all the work called for under the contract in all parts and requirements, is not finished or completed within the number of days as set forth, damage will be sustained by the CITY, and that it is and will be impracticable and extremely difficult to ascertain the actual damage which CITY will sustain in the event of and by reason of such delay; and it is therefore agreed that CONTRACTOR will pay to CITY the sum of ONE THOUSAND SEVEN HUNDRED FIFTY DOLLARS AND NO/100 DOLLARS ($1,750.00) per day for each and every calendar day's delay in finishing the work in excess of the number of days prescribed; and CONTRACTOR agrees to pay said liquidated damages as herein provided, and in case the same are not paid, agrees that CITY, may deduct the amount thereof from any monies due or that may become due CONTRACTOR under the contract.
It is further agreed that in case the work called for under the contract is not finished and completed in all parts and requirements within the number of days as specified, the CITY shall have the right to increase the number of days or not, as may seem best to serve the interest of CITY, and if the CITY decides to increase the said number of days, the CITY shall further have the right to charge to CONTRACTOR, CONTRACTOR's heirs, assigns or sureties, and to deduct from the final payment for the work, all or any part, as may be deemed proper, the liquidated damages as specified or the actual cost of engineering, inspection, superintendence, and other overhead expenses which are directly chargeable to the contract, and which accrue during the period of such extension, whichever is greater, except the cost of final surveys and preparation of final estimate shall not be included in such charges.
A working day shall not include, nor shall CONTRACTOR be assessed with liquidated damages nor the additional cost of engineering and inspection during any delay beyond the time named for the completion of the work caused by acts of God or of the public enemy, acts of CITY, fire, floods, epidemics, quarantine restrictions, strikes, and freight embargoes and subject to approval by the Director of Public Works, inability to get materials ordered by CONTRACTOR or subcontractor due to such causes provided that CONTRACTOR shall notify the Director of Public Works in writing of the causes of delay within five (5) working days from the beginning of any such delay, and the Director shall ascertain the facts and the extent of the delay, and Director's findings of the facts thereon shall be final and conclusive.
If CONTRACTOR is delayed by reason of alterations made in these specifications, or by any act of the Director of Public Works or of the CITY, not contemplated by the contract, the time of completion shall be extended proportionately and CONTRACTOR shall be relieved during the period of such extension of any claim for liquidated damages,
1103
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22017 (Updated 12/31/20)
engineering or inspection charges or other penalties. CONTRACTOR shall have no claim for any other compensation for any such delay.
7. CONFORMANCE TO APPLICABLE LAWS. Contractor shall comply with all applicable Federal, State, and Municipal laws, rules, and ordinances. Contractor shall not discriminate in the employment of persons or in the provision of services under this Contract on the basis of any legally protected classification, including race, color, national origin, ancestry, sex or religion of such person.
a. TITLE VI
Title VI of the Civil Rights Act of 1964 requires that “no person in the United States shall, on the grounds of race, color, or national origin, be excluded from participation in, be denied the benefits of, or be subjected to discrimination under any program or activity receiving federal financial assistance.” (42 USC Section 2000d)
http://www.dol.gov/oasam/regs/statutes/titlevi.htm.
The City of Stockton requires compliance with the requirements of Title VI in all of its programs and activities regardless of funding source. b. DISCRIMINATION AND HARASSMENT POLICY
The City of Stockton has a Discrimination and Harassment Policy (Exhibit C). The purpose of this policy is to reaffirm the CITY’s commitment to demonstrating respect for all individuals by strictly prohibiting discrimination and harassment, including sexual harassment in the workplace, to define the types of behavior and conduct prohibited by this policy, and to set forth a procedure for reporting, investigating, and resolving complaints of discrimination and harassment in the workplace.
c. LABOR STANDARDS PROVISIONS/CALIFORNIA LABOR CODE
The bidder shall understand that conditions set forth in Chapter 1, Part 7, Division 2 of the California Labor Code shall be considered part of the contract agreement.
https://leginfo.legislature.ca.gov/faces/codes_displayText.xhtml?lawCode= LAB&division=2.&title=&part=7.&chapter=1.&article=2.
d. PREVAILING WAGE
CONTRACTOR and any subcontractor shall pay each employee engaged in the trade or occupation not less than the prevailing hourly wage rate. In accordance with the provisions of Section 1770 of the Labor Code, the
1104
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22017 (Updated 12/31/20)
Director of Department of Industrial Relations of the State of California has determined the general prevailing wage and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for in Section 1773.1, apprenticeship or other training programs authorized by Section 3093 and similar purposes applicable to the work to be done. CONTRACTOR performing the work under this contract shall obtain a copy of the wage rate determination and shall distribute copies to each subcontractor. As the wage determination for each craft reflects an expiration date, it shall be the prime CONTRACTOR and each subcontractor's responsibility to insure that the prevailing wage rates of concern is current and paid to the employee.
i. The CONTRACTOR performing the work shall be responsible for obtaining a copy of the State wage rate determination. State wage rates may be obtained at
http://www.dir.ca.gov/OPRL/pwd/Determinations/Northern/Northern.pd f. The CONTRACTOR shall be responsible for posting said wage rates at a prominent location at the work site and shall maintain same in a good readable condition for the duration of the work.
ii. Should the CONTRACTOR choose to work on a Saturday, Sunday or on a holiday recognized by the Labor Unions, the CONTRACTOR shall reimburse the CITY the actual cost of engineering, inspection, superintendence, and or other overhead expenses which are directly chargeable to the contract. Should such work be undertaken at the request of the CITY, reimbursement will not be required. To conform strictly with the provisions of Division 2, Part 7, Chapter 1, Article 2, of the Labor Code of the State of California. To forfeit as a penalty to CITY the sum of TWENTY-FIVE AND NO/100 DOLLARS ($25.00) for each laborer, worker, or mechanic employed by CONTRACTOR, or by any subcontractor under CONTRACTOR, in the execution of this contract, for each calendar day during which any laborer, worker, or mechanic is required or permitted to work more than eight (8) hours and who is not paid the general prevailing rate of per diem wages for holiday and overtime work in violation of the provisions of Sections 1770 to 1781 of the Labor Code of the State of California. That all sums forfeited under the provisions of the foregoing sections shall be deducted from the payments to be made under the terms of this contract.
iii. The CONTRACTOR to whom the contract is awarded shall insure that the prime and each subcontractor will in accordance with Section 1776 of the Labor Code, maintain certified payroll records. A copy of said records shall be provided with each invoice to the Public Works
1105
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22017 (Updated 12/31/20)
Department, Attention Contract Compliance Officer. It shall be the CONTRACTOR’S responsibility to obtain copies of the current prevailing wage rate determination for all subcontractors. Additionally, certified payroll records must be uploaded to the DIR website as required by labor code.
iv. The CONTRACTOR shall comply with the provisions established in Section 1777.5 of the Labor Code concerning the 1) certified approval by local joint apprenticeship committees for the employment and training of apprentices, and 2) contribution of funds to administer and conduct apprenticeship programs, if applicable to the job. e. LOCAL EMPLOYMENT ORDINANCE
Pursuant to Stockton Municipal Code Section 3.68.095 the CONTRACTOR and all subcontractors shall make a good faith effort to employ at least 50 percent of the workforce on this project from local residents, as measured by total labor work hours. Failure of any CONTRACTOR or subcontractor to comply with these requirements shall be deemed a material breach of the contract or subcontract. CONTRACTORS and subcontractors shall maintain records necessary for monitoring their compliance with section
3.68.095.
CITY agrees:
8. COMPENSATION. To pay CONTRACTOR for the work herein
contemplated in the following manner: Progress payments will be made on or about the first day of each calendar month, in such sum as shall make the aggregate of payment up to such day equal to ninety-five percent (95%) of the proportional contract price, upon the basis of the progress certificate of the Director of Public Works as to the amount of work done and the proportional amount of the contract price represented therefore; and all of the remaining part of the contract price not as aforesaid paid, shall be paid at the expiration of thirty-five (35) days from the completion of said work of construction and the certification by the Director of Public Works of such completion.
9. SECURITIES. Pursuant to Section 22300 of the Public Contract Code, CONTRACTOR will be permitted, at its request and sole expense, to substitute securities for any monies withheld by the CITY to ensure performance under the contract. Said securities will be deposited either with the CITY or with a State or federally chartered bank as escrow agent. Securities eligible for this substitution are those listed in Section 16430 of the California Government Code or bank or savings and loan certificates of deposit.
CONTRACTOR shall be the beneficial owner of any securities substituted for monies withheld and shall receive any interest thereon.
1106
Local Construction Contract – UNITED PAVEMENT MAINTENANCE, INC. –PROJECT NO. WD22017 (Updated 12/31/20)
10. CHANGE ORDERS. CITY reserves the right to make such alterations, deviations, additions to or omissions from the plans and specifications, including the right to increase or decrease the quantity of any item or portion of the work, as may be deemed by the Engineer to be necessary or advisable and to require such extra work as may be determined by the Engineer to be required for the proper completion or construction of the whole work contemplated.
Any such changes will be set forth in a contract change order which will specify, in addition to the work done in connection with the change made, adjustment of contract time, if any, and the basis of compensation for such work. A contract change order will not become effective until approved by the City Manager and/or the City Council.
Processing of change orders shall be in accordance with Section 4-1.05A of the City of Stockton Standard Specifications and Plans as adopted by Council on September 27, 2016, by Resolution No. 2016-09-27-1213, effective September 27, 2016, or as otherwise amended by Council. When the compensation for an item of work is subject to adjustment under the provisions of Standard Specifications and Plans, Section 4-1.05A, CONTRACTOR shall, upon request, promptly furnish the Engineer with adequate detailed cost data for such item of work.
11. AUDITS. CITY reserves the right to periodically audit all charges made by CONTRACTOR to CITY for services under the contract. Upon request, CONTRACTOR agrees to furnish CITY, or a designated representative, with necessary information and assistance.
CONTRACTOR agrees that CITY or its delegate will have the right to review, obtain and copy all records pertaining to performance of the contract. CONTRACTOR agrees to provide CITY or its delegate with any relevant information requested and shall permit CITY or its delegate access to its premises, upon reasonable notice, during normal business hours for the purpose of interviewing employees and inspecting and copying such books, records, accounts, and other material that may be relevant to a matter under investigation for the purpose of determining compliance with this requirement.
CONTRACTOR further agrees to maintain such records for a period of three (3) years after final payment under the contract.
//
//
//
//
//
//
//
//
//
//
1107
1109
1110
1111
EXHIBIT A Page 14 of 42 EXHIBIT 2
1112
EXHIBIT A Page 15 of 42 EXHIBIT 2
1113
EXHIBIT A Page 16 of 42 EXHIBIT 2
1114
EXHIBIT A Page 17 of 42 EXHIBIT 2
1115
EXHIBIT A Page 18 of 42 EXHIBIT 2
1116
EXHIBIT A Page 19 of 42 EXHIBIT 2
1117
NOTE: The City of Stockton is now using the online insurance program PINS Advantage. Once you have been awarded a contract you will receive an email from the City’s online insurance program requesting you to forward the email to your insurance provider(s). Please see attached flyer regarding PINS Advantage.
Exhibit B:
Insurance Requirements for Construction Contracts
Contractor shall procure and maintain for the duration of the contract,and for five (5) years thereafter , insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, their agents, representatives, employees, or subcontractors. In the event contractor fails to obtain or maintain completed operations coverage as required by this agreement, the City, at its sole discretion, may purchase the coverage required and the cost will be paid by the contractor.
MINIMUM SCOPE AND LIMIT OF INSURANCE
Coverage shall be at least as broad as:
1. Commercial General Liability (CGL): Insurance Services Office (ISO) Form CG 00 01 covering CGL on an “occurrence” basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $2,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit.
2. Automobile Liability: Insurance Services Office Form CA 0001 covering Code 1 (any auto), with limits no less than $2,000,000 per accident for bodily injury and property damage.
3. Workers’ Compensation insurance as required by the State of California, with Statutory Limits, and Employers’ Liability insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.
4. Surety Bonds as described below.
5. Contractors’ Pollution Legal Liability and/or Asbestos Legal Liability with limits no less than $2,000,000 per occurrence or claim, and $2,000,000 policy aggregate.
It shall be a requirement under this agreement that any available insurance proceeds broader than or in excess of the specified minimum insurance coverage requirements and/or limits shall be available to the Additional Insured. Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this EXHIBIT B Page 20 of 42 EXHIBIT 2
1118
Agreement; or (2) the broader coverage and maximum limits of coverage of any Insurance policy or proceeds available to the named insured; whichever is greater. No representation is made that the minimum insurance requirements of this agreement are sufficient to cover the obligations of the Contractor under this agreement.
Limits of Insurance
The limits of insurance required in this agreement may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis before the City’s own insurance or self-insurance shall be called upon to protect it as a named insured.
Other Insurance Provisions
The insurance policies are to contain, or be endorsed to contain, the following provisions:
Additional Insured Status
The City of Stockton, its officers, officials, employees, and volunteers are to be covered as additional insureds on the CGL policy with respect to liability arising out of work or operations performed by or on behalf of the Contractor including materials, parts, or equipment furnished in connection with such work or operations. General liability coverage can be provided in the form of an endorsement to the Contractor’s insurance (at least as broad as ISO Form CG 20 10 11 85 or if not available, through the addition of both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 if a later edition is used). Additional insured Name of Organization shall read “City of Stockton, its officers, officials, employees, and volunteers.” Policy shall cover City of Stockton, its officers, officials, employees, and volunteers for all locations work is done under this contract.
Primary Coverage
The Additional Insured coverage under the Contractor’s policy shall be “primary and non-contributory” and will not seek contribution from the City’s insurance or selfinsurance and shall be at least as broad as CG 20 01 04 13. The City of Stockton does not accept endorsements limiting the Contractor’s insurance coverage to the sole negligence of the Named Insured.
Claims Made Policies – (Note – applicable only to professional and/or pollution liability)
If any coverage required is written on a claims-made coverage form:
EXHIBIT B Page 21 of 42 EXHIBIT 2
1119
1. The retroactive date must be shown, and this date must be before the execution date of the contract or the beginning of contract work.
2. Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of contract work.
3. If coverage is canceled or non-renewed, and not replaced with another claims-made policy form with a retroactive date prior to the contract effective, or start of work date, the Contractor must purchase extended reporting period coverage for a minimum of five (5) years after completion of contract work.
4. A copy of the claims reporting requirements must be submitted to the City of Stockton for review.
5. If the services involve lead-based paint or asbestos identification/remediation, the Contractors Pollution Liability policy shall not contain lead-based paint or asbestos exclusions. If the services involve mold identification/remediation, the Contractors Pollution Liability policy shall not contain a mold exclusion, and the definition of Pollution shall include microbial matter, including mold.
Notice of Cancellation
Each insurance policy required above shall provide that coverage shall not be canceled, except with notice to the City of Stockton.
Waiver of Subrogation
Contractor hereby grants to City of Stockton a waiver of any right to subrogation which any insurer of said Contractor may acquire against the City of Stockton by virtue of the payment of any loss under such insurance. Contractor agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation, but this provision applies regardless of whether or not the City of Stockton has received a waiver of subrogation endorsement from the insurer. The Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of the City of Stockton for all work performed by the Contractor, its employees, agents and subcontractors.
Self-Insured Retentions
All Self-insured retentions must be disclosed to Risk Management for approval and shall not reduce the limits of liability. The City of Stockton may require the Contractor to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention.
EXHIBIT B Page 22 of 42 EXHIBIT 2
1120
The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the named insured or City of Stockton.
Acceptability of Insurers
Insurance is to be placed with insurers with a current A.M. Best’s rating of no less than A:VII, unless otherwise acceptable to the City of Stockton.
Verification of Coverage
Contractor shall furnish the City of Stockton with original certificates and amendatory endorsements or copies of the applicable policy language effecting coverage required by this clause. All certificates and endorsements are to be received and approved by the City of Stockton Risk Services before work commences. However, failure to obtain the required documents prior to the work beginning shall not waive the Contractor’s obligation to provide them. The City of Stockton reserves the right to require complete, certified copies of all required insurance policies, including endorsements required by these specifications, at any time.
Contractor shall, prior to the commencement of work under this Agreement, provide the City of Stockton with a copy of its declarations page(s) and endorsement page(s) for each of the required policies.
Subcontractors
Contractors shall require and verify that all subcontractors, or other parties hired for this work, purchase and maintain coverage for indemnity and insurance requirements as least as broad as specified in this agreement to the extent they apply to the scope of the subcontractor’s work with the same certificate of insurance requirements and naming as additional insureds all parties to this contract. Contractor shall include the following language in their agreement with Subcontractors: Subcontractors hired by Contractor agree to be bound to Contractor and City in the same manner and to the same extent as Contractor is bound to City under the contract documents and provide a valid certificate of insurance and the required endorsements included in the agreement as proof of compliance prior to commencement of any work and to include this same requirement for any subcontractors they hire for this work. A copy of the owner contract document indemnity and insurance provisions will be furnished to the subcontractor upon request. Contractor shall provide proof of such compliance and verification to the City upon request.
Surety Bonds
Contractor shall provide the following Surety Bonds:
EXHIBIT B Page 23 of 42 EXHIBIT 2
1121
1. Bid bond
2. Performance bond
3. Payment bond (or Labor and Material bond)
4. Maintenance bond
The Payment Bond and the Performance Bond shall be in a sum equal to one hundred percent (100%) of the contract price. If the Performance Bond provides for a one-year warranty a separate Maintenance Bond is not necessary. If the warranty period specified in the contract is for longer than one year a Maintenance Bond equal to 10% of the contract price is required. Bonds shall be duly executed by a responsible corporate surety, authorized to issue such bonds in the State of California and secured through an authorized agent with an office in California.
Special Risks or Circumstances
City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances.
Certificate Holder Address
Proper address for mailing certificates, endorsements and notices shall be:
City of Stockton
Attn: City Risk Services
400 E Main Street, 3rd Floor – HR
Stockton, CA 95202
EXHIBIT B Page 24 of 42 EXHIBIT 2
1122
EXHIBIT C Page 25 of 42 EXHIBIT 2
1123
EXHIBIT C Page 26 of 42 EXHIBIT 2
1124
EXHIBIT C Page 27 of 42 EXHIBIT 2
1125
EXHIBIT C Page 28 of 42 EXHIBIT 2
1126
EXHIBIT C Page 29 of 42 EXHIBIT 2
1127
EXHIBIT C Page 30 of 42 EXHIBIT 2
1128
EXHIBIT C Page 31 of 42 EXHIBIT 2
1129
EXHIBIT C Page 32 of 42 EXHIBIT 2
1130
EXHIBIT C Page 33 of 42 EXHIBIT 2
1131
EXHIBIT C Page 34 of 42 EXHIBIT 2
1132
EXHIBIT C Page 35 of 42 EXHIBIT 2
1133
EXHIBIT C Page 36 of 42 EXHIBIT 2
1134
EXHIBIT C Page 37 of 42 EXHIBIT 2
1135
EXHIBIT C Page 38 of 42 EXHIBIT 2
1136
BOND FOR FAITHFUL PERFORMANCE
KNOW ALL MEN BY THESE PRESENTS:
That we, UNITED PAVEMENT MAINTENANCE, INC., a STATE OF
CALIFORNIA CORPORATION, as Principal and
, a corporation, organized and existing under the laws
of the State of and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, as obligee, in the just and full sum of ONE HUNDRED FIFTY THOUSAND FORTY DOLLARS 00/100 DOLLARS ($150,040.00), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to the said CITY, the said Principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.
The condition of the foregoing obligation is such that the above bounded Principal has simultaneously entered into a contract with the CITY, to do and perform the following work, to wit:
SIDEWALK REPLACEMENT
(PROJECT NO. WD22017)
NOW, THEREFORE, if the above bounded Principal, CONTRACTOR, Company or
Corporation or its subcontractor, shall well and truly perform the work contracted to be done under said contract, then this obligation to be null and void; otherwise to remain in full force and effect.
No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract, or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY, and no forbearance on the part of the said CITY shall operate to relieve any Surety or Sureties from liability on this bond, and consent by said Surety is hereby given, and the said Surety hereby waives the EXHIBIT 2 Page 39 of 43 1137
provisions of Sections 2819 and 2845 of the Civil Code of the State of California.
SIGNED AND SEALED on
APPROVED AS TO SURETY: By:
PRINCIPAL
SURETY
APPROVED AS TO FORM & CONTENT:
LORI M. ASUNCION
ACTING CITY ATTORNEY
By:
ATTORNEY-IN-FACT
By:
DEPUTY CITY ATTORNEY
1138
BOND FOR LABOR AND MATERIAL
KNOW ALL MEN BY THESE PRESENTS:
That we, UNITED PAVEMENT MAINTENANCE, INC., a STATE OF
CALIFORNIA CORPORATION, as Principal and ,
corporation, organized and existing under the laws of the State of and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto the City of Stockton, a municipal corporation, duly created and existing under and by virtue of the laws of the State of California, and unto any and all material suppliers, persons, companies, or corporations furnishing materials, provisions, provender or other supplies used in, upon, for or about the performance of the work contemplated to be executed or performed under the contract hereinafter mentioned, and all persons, companies, or corporations renting or hiring teams, or implements of machinery, for or contributing to said work and all persons who perform work or labor upon the same, and all persons who supply both work and materials, and whose claims have not been paid by the contractor, company or corporation in the just and full sum of ONE HUNDRED FIFTY THOUSAND FORTY DOLLARS AND 00/100 DOLLARS ($150,040.00), in lawful money of the United States of America (being 100% of the contract price) for the payment whereof well and truly to be made to said CITY and to said persons jointly and severally, the said principal and Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents.
The condition of the foregoing obligations is such that the above bounden Principal has simultaneously entered into a contract of even date herewith, with the CITY, to do and perform the following work, to-wit:
SIDEWALK REPLACEMENT
(PROJECT NO.WD22017)
NOW, THEREFORE, if the above bounden Principal, CONTRACTOR, Company or Corporation or its subcontractor, fail to pay for all materials, provisions, provender, or other supplies, or teams, used in, upon, for or about the performance of the work contracted to be done, or for any work or labor done thereon of any kind, the Surety on
EXHIBIT 2 Page 41 of 42 1139
this bond will pay the same, in an amount not exceeding the sum specified in this bond, provided that any and all claims hereunder shall be filed and proceedings had in connection therewith as required by the provisions of Division 3, Part 4, Title 15, Chapter 5, Article 1 of the Civil Code of California, provided that in case suit is brought upon this bond, a reasonable attorney's fee shall be awarded by the Court to the prevailing party in said suit; said attorney's fee to be fixed as costs in said suit, and to be included in the judgment therein rendered.
No prepayment or delay in payment and no change, extension, addition or alteration of any provision of said contract or in said plans or specifications agreed to between the said CONTRACTOR and the said CITY and no forbearance on the part of the said CITY shall operate to relieve any surety or sureties from liability on this bond, and consent to make such alterations without further notice to or consent by any such surety is hereby given, and the said sureties hereby waive the provisions of Sections 2819 and 2845 of the Civil Code of the State of California.
SIGNED AND SEALED on .
APPROVED AS TO SURETY: By:
PRINCIPAL
SURETY
APPROVED AS TO FORM & CONTENT:
LORI M. ASUNCION
ACTING CITY ATTORNEY
By:
ATTORNEY-IN-FACT
By:
DEPUTY CITY ATTORNEY
1140
City of Stockton
Legislation Text
File #: 22-0704, Version: 1
ADOPT RESOLUTION TO AUTHORIZE THE CITY STREET RE-STRIPING FY 2021-22 SB1
PROJECT
RECOMMENDATION
It is recommended that the City Council adopt a resolution to:
1. Approve Notice of Exemption No. NOE20-22 under the California Environmental Quality Act for the City Street Re-Striping FY 2021-22 SB1, Project No. WD22009.
2. Approve the plans and specifications for the City Street Re-Striping FY 2021-22 SB1, Project No. WD22009.
3. Award a Construction Contract in the amount of $297,315 to Chrisp Company of Stockton, CA, for the City Street Re-Striping FY 2021-22 SB1, Project No. WD22009.
It is also recommended that the City Manager be authorized to take appropriate and necessary actions to carry out the purpose and intent of this resolution.
Summary
The project will re-stripe 78 intersections citywide and includes additional lane line striping (Attachment A). The improvements include refreshing crosswalks, limit lines, and pavement legends that are worn. The project was included in the 2021-26 Five-Year Capital Improvement Plan (CIP).
On June 9, 2022, the City received one bid for this project. Staff recommends award of the Construction Contract to the only responsive bidder, Chrisp Company, in the amount of $297,315.
Staff also recommends that Council adopt a resolution approving Notice of Exemption No. NOE20-22 under the California Environmental Quality Act (CEQA) and approving the plans and specifications for the project. Construction is anticipated to begin and be completed in the Fall 2022, weather permitting.
DISCUSSION
Background
On April 28, 2017, the Governor signed Senate Bill 1 (SB1), known as the Road Repair and Accountability Act of 2017. SB1 provides the first significant, stable, and ongoing increase in State transportation funding in more than two decades. The funding provides for basic road maintenance, rehabilitation, and critical safety needs on both the State highway and local streets and road systems.
The California Transportation Commission (CTC) is responsible for oversight of funding and/or City of Stockton Page 1 of 3 Printed on 9/7/2022
powered by Legistar™
1141
File #: 22-0704, Version: 1
programs created with the approval of SB1.
SB1 provides funding for the Road Maintenance and Rehabilitation Account (RMRA) Program. Other programs include the Local Partnership Program, the Active Transportation Program, State Highway Operation and Protection Program, and Local Streets and Roads Program. The RMRA funding is part of the City's overall Gas Tax allocation; however, RMRA funds can only be expended on projects that meet eligibility criteria and have been approved by the CTC. RMRA funds are accounted for and reported separately from regular Gas Tax funds. An estimated $6.2 million in SB1 RMRA Program funding was allocated to the City for Fiscal Year (FY) 2021-22, and the project list was approved by Council on May 11, 2021, by Resolution No. 2021-05-11-1208.
The City Street Re-Striping FY 2021-22 SB1 project was included in the 2021-26 Five-Year CIP. The project will re-stripe 78 intersections citywide and includes additional lane line striping (Attachment A). The improvements include refreshing crosswalks, limit lines, and pavement legends that are worn. Existing worn traffic stripes and markings will be primed, and a new coat of thermoplastic material will be applied. Thermoplastic comprises plastic, binders, and glass beads to provide durability and retro-reflectivity to aid nighttime driving. The application is anticipated to last approximately five years. The selection criteria for this project was developed by visual inspection of the roads, existing work orders, and citizen requests.
On July 26, 2016, Council adopted a Community Workforce and Training Agreement (CWTA). The CWTA became effective August 25, 2016, and applies to all Public Works projects over $1 million that are bid after that date. On July 16, 2019, by Motion No. 2019-07-16-1403, Council extended the CWTA term to August 25, 2024. The CWTA was not applied to this project as the estimated construction cost is less than $1 million.
Present Situation
On May 19, 2022, the City Street Re-Striping FY 2021-22 SB1, Project No. WD22009, was advertised for bids. On June 9, 2022, one bid was received from Chrisp Company of Stockton, CA, in the amount of $297,315. The Engineer’s Estimate was $300,107.40.
The requirements of Stockton Municipal Code (SMC) section 3.68.090, Local Business Preference, apply to this project. Application of the Local Business Preference has no effect on the bid order, as only one bid was received. The Local Employment Ordinance, SMC section 3.68.095, also applies to this contract.
The bid from Chrisp Company, the only responsive bidder, is regular in all respects and has the proper license to perform the work. Staff recommends Council approve the plans and specifications for the project and award a Construction Contract to Chrisp Company of Stockton, CA, in the amount of $297,315.
The project is in conformance with the City's General Plan, pursuant to California Government Code, section 65402, and is categorically exempt from the requirements of CEQA as specified under Section 15301(c) of the CEQA Guidelines. As a result, the project has been granted a Categorical Exemption. The activities related to this project constitute a discretionary project under the City's jurisdiction and qualifies as a project that does not have a significant effect on the environment. The City of Stockton Page 2 of 3 Printed on 9/7/2022
powered by Legistar™
1142
File #: 22-0704, Version: 1
resolution will approve the filing of Notice of Exemption No. NOE20-22 under CEQA. Construction is anticipated to begin and be completed in fall 2022, weather permitting.
FINANCIAL SUMMARY
Council approved RMRA funding in the amount of $306,000 on May 11, 2021, by Resolution No. 2021-05-11-1208, and appropriated funding to the City Street Re-Striping FY 2021-22 SB1, Project No. WD22009, Account No. 4570-715-800007-240-241-30-45-000-000. There is sufficient funding in the project to award a Construction Contract to Chrisp Company in the amount of $297,315.
There is no impact on the City's General Fund or any other unrestricted fund as a result of taking the recommended actions.
Attachment A - Vicinity Map
City of Stockton Page 3 of 3 Printed on 9/7/2022
powered by Legistar™
1143
Ã4
Ã4
Ã4
Ã4
Ã4
Ã4
Ã4
§¨5
§¨5
§¨5
§¨5
§¨5
§¨5
§¨5
Ã26
Ã2
Ã26
Ã26
Ã88
Ã99
Ã99
Ã99
Ã99
Ã99
HOLT DR
MARCH LN
D
O
R
A
DO
ST
HARDING WY FREMONT ST
DR MLK JR BL
AIRPORT
WY
PACIFIC AV
PERSHING AV
MAIN ST EL D
O
RADO ST
WATERLOO RD
CHEROK
WILSON WY
ALPINE AV ROBERTS RD MATHEWS RD
CHARTER WY
!! !! !!!!!! !! !!!!
!!!!!!
!!
!!!
!
!!
!!!!
!!
!!
!!!!
!!
!!
!!
!!
!!
!!
!!
!!
!! !!
!!
!!!!
!!!!
!!
!!
!!
!!
!!
!!
!!!!
!!
!!
Vicinity Map
City Street Re-striping FY21-22 SB1,
Project No. WD22009
Legend
!! Intersections
Parks
Public Schools
IN/OUT
0 0.55 1.1 1.65 2.2 0.275
County Limits µ
Miles
EIGHT MILE RD RD ROBERTS RD
HOWARD RD MAIN ST PERSHING AV
EL DORADO ST EIGHT MILE RD
DAV SI RD THORNTON RD
EL DORADO ST WEST LN
PAC IFIC AV MARCH LN
ALPINE AV CH EROKE RD
AIRPORT WY CENTER ST
FRENCH CAMP RD MAIN ST AIRPO RT WY CHEROKEE RD
ROBERTS RD
HOWARD RD
LOW ER S ACR AM ENTO R D WILSON W Y
PACIFIC AV DR MLK JR BL MARIPO SA RD
HOLMA N RD
HOLMAN RD
TRINITY PK WEST LN MORADA LN
THORNTO N RD
HAMMER LN
HAMMER LN PER SHING AV
BENJ.HOLT DR MARC H LN
HARDING WY WEST LN WATER LO O RD WILSON WY NAVY DR
EIGHTH ST
FREN CH CA M P RD
FREMONT ST SPERRY RD
ARCH AIRPORT RDMARCH LN MATHEWS RD
EL DORADO ST CHARTER WY
Lane Lines &
Intersections
ATTACHMENT A 1144
Resolution No.
STOCKTON CITY COUNCIL
RESOLUTION APPROVING THE NOTICE OF EXEMPTION NO. NOE20-22,
APPROVING THE PLANS AND SPECIFICATIONS, AND AWARDING A
CONSTRUCTION CONTRACT FOR THE CITY STREET RE-STRIPING FISCAL YEAR 2021-22 SB1, PROJECT NO. WD22009
On June 9, 2022, the City Clerk of the City of Stockton opened, examined, and publicly declared the sealed proposals or bids offered for the City Street Re-Striping Fiscal Year (FY) 2021-22 SB1, Project No. WD22009; and
The project will re-stripe 78 intersections citywide and includes additional lane line striping. The improvements include refreshing crosswalks, limit lines, and pavement ledges that are worn; and
Chrisp Company is the only responsive bidder in the amount of $297,315, and its bid is regular in all respects; and
The project is categorically exempt from the requirements of the California Environmental Quality Act (CEQA) as specified under section 15301(c) of the CEQA Guidelines, because this is a discretionary project under the City’s jurisdiction and qualifies as a project which has been determined to not have a significant effect on the environment; now, therefore,
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF STOCKTON, AS FOLLOWS:
1. The City Council approves the filing of Notice of Exemption No. NOE20-22 under the CEQA for the City Street Re-Striping FY 2021-22 SB1, Project No. WD22009, a copy of which is attached as Exhibit 1 and incorporated by this reference.
2. The City Council approves the plans and specifications for the City Street Re-Striping FY 2021-22 SB1, Project No. WD22009.
3. The City Council awards a Construction Contract between the City of Stockton and Chrisp Company in the amount of $297,315, and the City Manager is authorized and directed to execute same, a copy of which is attached as Exhibit 2 and incorporated by this reference.
//
//
//
//
//
1145
4. The City Manager is hereby authorized to take whatever actions are necessary and appropriate to carry out the purpose and intent of this Resolution.
PASSED, APPROVED, and ADOPTED September 13, 2022 .
________________________
KEVIN J. LINCOLN II
Mayor of the City of Stockton
ATTEST:
__________________________
ELIZA R. GARZA, CMC
City Clerk of the City of Stockton
1146
EXHIBIT 1 1147
Local Construction Contract – CHRISP COMPANY –PROJECT NO. WD22009 (Updated 12/31/20)
CONSTRUCTION CONTRACT
This contract is made and entered into on _____________, by and between CHRISP COMPANY, a STATE OF CALIFORNIA CORPORATION, with a business address at 1001 STOKES AVENUE, STOCKTON, CA 95215, hereinafter called "CONTRACTOR," and CITY OF STOCKTON, a municipal corporation, hereinafter called "CITY."
W I T N E S S E T H:
WHEREAS, plans and specifications for the construction of CITY STREET RESTRIPING FY 2021-22 SB1 (PROJECT NO. WD22009), hereinafter called “PROJECT,” were regularly adopted by Council Resolution No. __________________, on _________________; and
WHEREAS, the contract for said work was regularly awarded to CONTRACTOR, by Council Resolution No. __________________, on ________________.
NOW, THEREFORE, in consideration of the promises and of the mutual covenants herein contained, the parties hereto expressly agree as follows:
CONTRACTOR agrees:
1. SCOPE OF SERVICES. To do the work and furnish all the labor, materials, tools, equipment, and insurance required for the construction of PROJECT in accordance with the plans and specifications adopted on _____________, by Council Resolution No. __________________ . The "contract documents," which include the bid documents, project plans, specifications, all letters of clarification, and the City of Stockton Standard Specifications and Plans, are incorporated into and made a part of this contract by this reference to the same extent as if fully set forth.
2. COMPENSATION. To do and perform the work contemplated hereby in a good and workmanlike manner and to furnish all labor, materials, tools, and equipment necessary therefore at the prices specified in Exhibit A, attached hereto and by reference made a part hereof, under the direction of and to the complete satisfaction of the Director of Public Works of the City of Stockton. Total compensation for services and reimbursement for costs shall not exceed $297,315.00, or as otherwise mutually agreed to in a Contract Change Order.
3. INSURANCE. CONTRACTOR shall not commence any work before obtaining, and shall maintain in force at all times during the duration and performance of this contract, the policies of insurance specified in Exhibit B, which is attached to this contract and incorporated by this reference, and as provided in the “contract documents” including Section 7-1.06 of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27, effective September 27, 2016.