City Council and Concurrent Authorities
November 4, 2025

Changes to Contract Cost:

A
mendment No. 12 provides $186,000 for additional design construction support services estimated to provide service through 12/31/25. The work will continue to be billed on a time-and-material basis based on the updated rates provided by Amendment No. 7. The total adjusted NTE amount is changed to $5,948,133. by this Amendment No. 12. Further amendment will be required to complete the project.

Co
ntract Summary
Original Contract Total NTE amount $1,392,900.

Added by Amendment #1, 6/30/20 $105,743.

Added by Amendment #2, 2/3/21 $527,147.

Added by Amendment #3, 6/3/21 $14,900.

Added by Amendment #4, 11/22/21 $175,443.

Added by Amendment #5, 3/14/22 $600,000.

Added by Amendment #6, 3/29/23 $380,000.

Added by Amendment #7, 4/3/23 $820,000.

Added by Amendment #8, 4/8/24 $396,000.

Added by Amendment #9, 10/25/24 $750,000.

Added by Amendment #10, 3/24/25 (time extension only) $0.

Added by Amendment #11, 6/12/25 $600,000.

Added by this Amendment #12, 7/31/25 $186,000.

Total Adjusted NTE amount $5,948,133.

T
he revised Task Price table is as follows, monthly invoicing to be adjusted accordingly.

Current
Authorized Task
Price
Change This
Amendment
Adjusted Task
Price
STEP #1 - KICK-OFF MEETING $13,400.00 $0.00 $13,400.00
STEP #2 - SCHEMATIC PLAN $110,100.00 $0.00 $110,100.00
STEP #3 - CONFIRM DIRECTION $38,293.00 $0.00 $38,293.00 STEP #4 - CONSTRUCTION DOCUMENTS, 30% PS&E $540,550.00 $0.00 $540,550.00 STEP #5 - CONSTRUCTION DOCUMENTS, 60% PS&E $592,516.15 $0.00 $592,516.15 STEP #6 - CONSTRUCTION DOCUMENTS, 90% PS&E $554,116.15 $0.00 $554,116.15 STEP #7 - 100% PS&E AND PERMITTING $284,157.70 $0.00 $284,157.70 STEP #8 - BIDDING PHASE $83,000.00 $0.00 $83,000.00
STEP #9 - CONSTRUCTION PHASE $3,546,000.00 $186,000.00 $3,732,000.00 $5,762,133.00 $186,000.00 $5,948,133.00
Task Description

TOTAL PRICE, NTE FEE
Regards,
B
ruce Playle, Architect, AIA
Licensed Architect C15459
INDIGO/ Hammond & Playle Architects, LLP

ATTACHMENT B

Updated 12/26/24
Vendor: Date: 07/07/25
Dept: Contract/PO Number: 419000420
Account # Requestor: Joshua Lewis
1,392,900.00$
12/17/19
Original Contract Council Approval Date: 12/17/19
06/30/22
5,948,133.00$
4,555,233.00$
Effective Date: Dec 2, 2021
CM Authority: $ 100,000 07/31/26

D M WD CM CC
CURRENT BALANCES OF CCOs
Last Council Action 3,769,233.00$ 11/12/24 5,162,133.00$ 616, 213.30$ Total approved CCOs since last Council Action 600,000.00$ 1 49 5,762,133.00$ 16,213.30$ NEW PROPOSED CCOs
5,762,133.00$ 616,213.30$
12 Design construction support services 186,000.00$ 0 0 0 Y 5,948,133.00$ ( 169,786.70)$ Current CCO amount 186,000.00$
PREVIOUSLY APPROVED CCOs
Original Contract Y 12/17/19 1,392,900.00$
1 Design revisions, air/water survey and fire consultant services 105,743.00$ 0 6 0 Y 1,498,643.00$ 2 Additional design services for design revisions, HVAC replacement, floor/structural analysis, building waterproofing and exterior paint 527,147.00$ 0 0 0 Y 03/09/21 2,025,790.00$ 3 Geotechnical Engineering Services 14,900.00$ 0 0 0 Y 2,040,690.00$ 4 Additional design revision and bidding support services 175,443.00$ 0 0 0 Y 2,216,133.00$ 5 Design construction support services 600,000.00$ 1 24 0 Y 05/03/22 2,816,133.00$ 6 Design construction support services 380,000.00$ 0 0 0 Y 3,196,133.00$ 7 Design construction support services 820,000.00$ 0 0 0 Y 12/12/23 4,016,133.00$ 8 Change in Scope 396,000.00$ 0 7 0 Y 4,412,133.00$
9 Design construction support services 750,000.00$ 0 0 0 Y 11/12/24 5,162,133.00$ 10 Extends Contract Expiration Date -$ 0 12 0 Y 5,162,133.00$ 11 Design construction support services 600,000.00$ 0 0 0 Y 5,762,133.00$ Previous CCO Amount -----> 4,369,233.00$ 1 49 11/12/2024 5,162,133.00$ Total CCO Amount and Time Extension To-Date -----> 4,555,233.00$ 1 49 Revised
Contract Amount
Revised
CCO Authority Balance
Required
Approval
by:

Date CC
Approved
(mm/dd/yy)CCO No. Description
Requested
CCO Amount
Time
Extensions

ENTRIES IN BOLD RED INDICATE
YOUR BALANCE OF CM AUTHORITY CCO AMOUNT IS EXCEEDED.

YOU MUST GO TO COUNCIL FOR APPROVAL.

Original Contract Amount:

Original Contract Award Date:

Original Contract Expiration Date:

Contract Amount to date:

Authorized CCO Amount to date:

Contract Expiration to date:

CHANGE ORDER CALCULATOR
Indigo Hammond + Playle Architects, LLP
Public Works
E016015 / 4510-418-800007-300-000-30-45-000-000-

ATTACHMENT B
1 (Rev. 7.7.23)

CITY OF STOCKTON

PROFESSIONAL SERVICES CONTRACT AMENDMENT
This Amendment Number 8 to the above referenced Professional Services Contract, is entered into on _________________________, between the City of Stockton (“City”) and GRIFFIN STRUCTURES, INC. (“Consultant”) for the CONSTRUCTION MANAGEMENT FOR THE NEW CITY HALL RENOVATIONS AND RELOCATION, Project No. E016015.

RECITALS
Section 11, Contract Amendments, states that the Professional Services Contract may be amended only by written instrument signed by Consultant and City; and
The City needs to increase the Compensation, not to exceed amount in Section 2 of the Professional Services Contract and Exhibit B, by $400,000 to pay the Consultant for additional services; and Now therefore, the City and the Consultant mutually agree as follows:

1. The maximum not to exceed amount to be paid to the Con sultant, including if authorized, reimbursement of expenses, in Section 2 of the Professional Services Contract and Exhibit B, will now read as follows:
“T
he maximum not to exceed amount in Section 2 of the Professional Services Contract and Exhibit B , is amended to $2,891,761.”

2. City shall pay Consultant for additional changes in scope outlined in Exhibit A.

All other terms and conditions of the Professional Services Contract shall remain unchanged and remain in full force and effect unless modified by a written amendment signed by both parties.

IN
WITNESS WHEREOF, the authorized parties have executed this Contract.

CONSULTANT
________
_________________________________________________________________________ _ _ Consultant’s Name (if other than an individual, state whether a corporation, partnership, etc.) ________
_______________________________________________________________________ _____ Authorized Signature Date
________
_____________________________________________________________________ _______ Printed Name and Title of Person Signing
________
____________________________________________________________________ _______ Address

CITY OF STOCKTON
________
______________________________________________________________ ______________ Will Crew, Acting City Manager Date
ATT
EST:
________
_______________________________________________________________________ _____ Katherine Roland, CMC, CPMC, City Clerk
APPRO
VED AS TO FORM:

Lori M. Asuncion, City Attorney
BY:

Contract
Number:

Amendment
Number:
422000450

8 GRIFFIN STRUCTURES, INC.

9/16/2025
Robert Godfrey, V.P. of Operations
1 Technology Dr., Bldg. I, #829, Irvine, CA 92618

ATTACHMENT C

GRIFFIN STRUCTURES FEE PROPOSAL – AMENDMENT 08
Stockton City Hall Project
August 5, 2025
G
riffin Structures’ Fee Proposal is based on all reasonable costs necessary to perform Construction Management services for the Stockton City Hall project. For these requisite services Griffin Structures proposes the following Time and Materials Fee:

Construction Management: $ 263,790

Scheduling $ 0
Special Inspection & Testing $ 133,572
Submittal Exchange Extensions $ 0
Insurance Expenses: $ 2,638
Total $ 400,000
All proposed hourly rates are fully burdened and include overhead, profit, taxes, and benefits. The hours identified for each individual employee and task are estimates only and are not to be construed as not to exceed hours for any individual task, phase, or time period. We reserve the right to reallocate hours between staff members and tasks, in consultation with SupplyBank staff, in order to accomplish the overall objectives and requirements of the project.

SCOPE OF SERVICES
As of the issuance of Amendment 05, the project was anticipated to be completed by June of 2025. Due t
o changes in scope and unforeseen circumstances, the project is now expected to reach substantial completion in December 2025, with closeout occurring in first quarter 2026. This amendment covers the extension of services through December 2025.

Due to the added scope and the contractor’s prosecution of work, additional Special Inspections and Testing are also required for a total of $133,572 including the added fire stopping inspection.

APPROACH TO STAFFING & PROJECT TEAM
To bring the highest level of efficiency and value to the City, Griffin Structures has assembled following t
eam:

Robert Godrey will continue to support the project as Project Executive.

Hernan Munayco will remain as the on-site Sr. Construction Manager.

Andrew Simmons will continue as a Construction Manager.

EXHIBIT A

ATTACHMENT C

QUALIFICATIONS & EXCLUSIONS

1. H ourly rates are valid through December 31st, 2025 and will escalate by CPI annually thereafter.

2. Insurance costs are included as a reimbursable expense and will be billed monthly at the rate of $10 per $1,000.

3. On-site trailer rental, furniture, utilities, and sanitary facilities for our field staff (Project Management team) are excluded. We assume that offices will be provided as part of the construction site trailer(s) being provided by the City or its contractor.

4. Costs for all permits required for the project are excluded. It is assumed that the City will pay for all permitting fees, assessments, easements, school fees, and other agency or governmental fees or costs to support the design and construction the project. We have not included any permit related fees within our fee proposal. Permits will be pulled by others.

5. Costs for construction staking, environmental and hazardous materials surveys, and all environmental and hazardous materials transportation and remediation costs are excluded.

6. Software licenses or user fees and all software training costs for specific project management software being required by either the City or their contractor(s) are excluded.

7. Cost of bulk blueprinting for plans and specifications for use by the contractors and subcontractors is excluded. Funds included in reimbursable expenses are for Griffin printing costs alone.

8. Independent or third-party testing companies such as Roofing, Peer Reviews, LEED, or other specialized third-party oversight services other than those listed herein are excluded.

9. No FF&E or OS&E procurement is included in this proposal.

10. Construction Site Security is excluded.

11. This proposal does not include a formal independent Inspector of Record (IOR); it is assumed that any Building Department inspections will be performed by the City’s Building Department inspections staff. It does include an Add Alternate for a Quality Assurance Inspector.

12. Construction Manager will review all RFI’s, Submittals, and Substitutions only for completeness.

Approvals shall be executed by the architect of record.

13. Construction Cost Estimates, when provided, are based on standard industry practice, professional experience, and knowledge of market conditions. Griffin has no control over material and labor costs, contractor’s methods of establishing prices or the market and bidding conditions at the time of bid. Therefore, Griffin does not guarantee that bids received will not vary from the cost estimate provided and Griffin is not liable for any costs, liabilities, or damages incurred by the City arising from Griffin’s opinion of cost, the actual project cost to the City, delays caused by events outside the control of Griffin, or any labor or material cost increases.

14. Griffin is not responsible for, and the City will hold Griffin harmless from, any schedule delays and/or any losses, damages, or liabilities resulting therefrom that are caused by (1) events or

EXHIBIT A

ATTACHMENT C

conditions that are outside of Griffin’s control or (2) the acts or omissions of parties for whom G
riffin is not legally liable (collectively, “Non-Consultant Delays”). The schedule for completion will be extended for any Non-Consultant Delays. If Griffin incurs additional costs or expenses due to Non-Consultant Delays, then Griffin’s fee compensation will be equitably adjusted to cover such additional costs or expenses.

15. For document tracking control, Griffin has included the use of Autodesk for managing construction documentation, and based the hours allocated in this proposal accordingly. The cost of this system is included here as a reimbursable expense.

16. FF&E services are included and management and oversight of the effort to be performed by the selected design team professionals.

17. Move management services are included as oversight only. Griffin will nonetheless oversee the solicitation, negotiation, and oversight of the move management consultant, but will not be providing the service itself.

18. Commissioning requirements are understood as per California Building Cod / Cal Green (Title 24) only. LEED Commissioning is excluded.

EXHIBIT A

ATTACHMENT C
Updated 12/26/24
Vendor: Date: 05/22/25
Dept: Contract/PO Number: 422000450
Account # Requestor: Joshua Lewis
722,000.00$
11/16/21
Original Contract Council Approval Date: 11/16/21
12/31/24
2,891,761.00$
2,169,761.00$
Effective Date: Dec 2, 2021
CM Authority: $ 100,000 12/31/25

D M WD CM CC
CURRENT BALANCES OF CCOs
Last Council Action 1,469,761.00$ 11/12/24 2,191,761.00$ 319,176.10$ Total approved CCOs since last Council Action 300,000.00$ 12 2,491,761.00$ 19,176.10$ NEW PROPOSED CCOs
2,491,761.00$ 319,176.10$
8 Additional Construction Management Services 400,000.00$ Y 2,891,761.00$ (380,823.90)$ Current CCO amount 400,000.00$
PREVIOUSLY APPROVED CCOs
Original Contract Y 11/16/21 722,000.00$
1 Additional Construction Management Services 169,832.00$ 0 0 0 Y 891,832.00$ 2 Additional Material Testing Services 288,464.00$ 0 0 0 Y 12/12/23 1,180,296.00$ 3 Additional Material Testing Services 209,960.00$ 0 0 0 Y 1,390,256.00$ 4 Additional Construction Management Services 358,940.00$ 0 0 0 Y 06/18/24 1,749,196.00$ 5 Additional Construction Management Services 442,565.00$ 0 0 0 Y 11/12/24 2,191,761.00$ 6 Extending Expiration Date of Contract -$ 0 12 0 Y 2,191,761.00$ 7 Additional Construction Management Services 300,000.00$ 0 0 0 Y 2,491,761.00$ Previous CCO Amount -----> 1,769,761.00$ 12 11/12/2024 2,191,761.00$ Total CCO Amount and Time Extension To-Date -----> 2,169,761.00$ 12 Revised
Contract Amount
Revised
CCO Authority Balance
Required
Approval
by:

Date CC
Approved
(mm/dd/yy)CCO No. Description
Requested
CCO Amount
Time
Extensions

ENTRIES IN BOLD RED INDICATE
YOUR BALANCE OF CM AUTHORITY CCO AMOUNT IS EXCEEDED.

YOU MUST GO TO COUNCIL FOR APPROVAL.

Original Contract Amount:

Original Contract Award Date:

Original Contract Expiration Date:

Contract Amount to date:

Authorized CCO Amount to date:

Contract Expiration to date:

CHANGE ORDER CALCULATOR
Griffin Structures, Inc.

Public Works
E016015 / 4510-418-800007-300-000-30-45-000-000-

ATTACHMENT C

CITY OF STOCKTON
Contract Change Order #: ---=2=-=6'----
Resolution No. 2024-12-03-1504 Contract No.
(If not required enter "NIA')
422000787
Contract#

August 13, 2025
NEW CITY HALL RENOVATIONS AND RELOCATION, CITY PROJECT NO. E016015 Project Number I Project Name I Activity
Oriqinal Contract Price $42,348,123.00
Prior Chanqe Order Total $14,231,317.28
This Chanqe Order $496,820.18
Revised Contract Price $57,076,260.46
TO Roebbelen Contractina. Inc. (Contractor). You are hereby directed to make the herein described changes from the plans and specifications or do the following described work not included in the plans and specifications of this contract.

Additional Work Performed for Above Referenced Project
See Pages 2-4.
"The critical path schedule is currently being evaluated by the City as of the execution of this Change Order. Accordingly, the parties agree that any time extensions and time related costs associated with certain changes identified on the attached pages are excluded from this Change Order and, if later determined warranted, will be deferred to a future change order."
We, the undersigned contractor, have given careful consideration to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all materials, except as may otherwise be noted above, and perform all services necessary for the work above specified, and will accept as full payment therefore the prices shown above.

By reason of this proposed change, Q days extension of time will be allowed.

Accepted Date ________________ _
ROEBBELEN CONTRACTING, INC.
(Contractor)
PROCESSED By ____________________ _

UNILATERALLY
Title ____________________ _
Note: This contract change order is not effective until approved b the Ci Mana er.

APPROVED AS TO FORM & CONTENT:

OFFICE OF THE CITY ATTORNEY
BY __________ _
Date: _________ _
ATTEST:

KATHERINE ROLAND, CMC, CPMC

CITY CLERK OF THE CITY OF STOCKTON
Fully Executed Form Routing: Original to City Clerk; Copy to Vendor Approval Recommended by:
_______________ Date: _____ _
Chad Reed, Deputy City Manager I Interim Public Works Director Change Order Approved By:
_ ______________ Date:. _____ _
Will Crew, Acting City Manager

ATTACHMENT D
CITY OF STOCKTON Page 2 of 4
August 13, 2025
Fully Executed Form Routing: Original to City Clerk; Copy to Vendor Con
tract Change Order #: 26
Resolution No. _ 2024-12-03-1504_____ Contract No. ___422000787___ (If not required enter “N/A”) Contract #
NEW CITY HALL RENOVATIONS AND RELOCATION, CITY PROJECT NO. E016015 TO Roebbelen Contracting, Inc. (Contractor). You are hereby directed to make the herein described changes from the plans and specifications or do the following described work not included in the plans and specifications of this contract.

EXTRA WORK AT AGREED LUMP SUM
In accordance with Section 4 -1.05A of the City of Stockton Standard Specifications, the Contractor is directed to provide the following additional items of work:
1) ROOM R
EVISIONS IN BUILDINGS 1 & 2
Prep,
paint, patches, and electrical T&M work for FOD 208.1 - T&M for Building 1 & 2 – PCO 305E. The critical path schedule is currently being evaluated; any potential delays will be part of a future contract change order. (FOD #208.1e)
Agree
d Lump Sum Price: $ 18,753.65
2) TEMPO
RARY HEATERS REMOVAL IN BUILDINGS 1 & 2
Remove t
he temporary heaters from Fall 2024 and clean up surrounding areas in April – PCO 310E. The critical path schedule is currently being evaluated; any potential delays will be part of a future contract change order. (FOD #251.6)
Agree
d Lump Sum Price: $ 30,531.95
3) RAI
NWATER LEADERS REPAIR & PIPELINE REPAIR IN BUILDINGS 1 & 2 Repai
r rainwater leaders on buildings 1 & 2 level 5, and pipeline repair – PCO 324B. The critical path schedule is currently being evaluated; any potential delays will be part of a future contract change order. (FOD #254.1B)
Agree
d Lump Sum Price: $ 21,436.88
4) SLAB
EDGE/SILL TOPPING REPAIRS IN BUILDING 2
Repai
r existing slab edge and sill topping perimeter at Building 2 – PCO 357. The critical path schedule is currently being evaluated; any potential delays will be part of a future contract change order. (FOD #266.1)
Agree
d Lump Sum Price: $ 20,025.32
5) DRAIN LI
NE INVESTIGATIONS IN BASEMENT OF BUILDING 2
Pref
orm drain line investigation for both the floor drain and lift station vault. Gather CCTV footage, existing conditions, and clean – PCO 358. The critical path schedule is currently being evaluated; any potential delays will be part of a future contract change order. (FOD #278.1A) Agree
d Lump Sum Price: $ 6,634.70

ATTACHMENT D
CITY OF STOCKTON Page 3 of 4
August 13, 2025
Fully Executed Form Routing: Original to City Clerk; Copy to Vendor 6) PO

THOLING AND HYDRO VAC IN PUBLIC PARKING LOT
Ex
plore, pothole, and hydro vac at new asphalt areas including the driveway – PCO 359. The critical path schedule is currently being evaluated; any potential delays will be part of a future contract change order. (FOD #287.1)
Agr
eed Lump Sum Price: $ 12,504.72
7) INS
TALL ADDITIONAL EDGE OF CONCRETE DECK FIRE STOPPING IN BUILDING 2 Ins
tall fire stopping materials such as mineral wool, caulking, and cafco 300, at edge of deck conduit penetrations – PCO 330. The critical path schedule is currently being evaluated; any potential delays will be part of a future contract change order. (FOD #296.1) Agr
eed Lump Sum Price: $ 10,546.20
8) GE

OTEXTILE FABRIC ADDITION IN COURTYARD
Add
geotextile fabric to new courtyard per special inspection requirements – PCO 371. The critical path schedule is currently being evaluated; any potential delays will be part of a future contract change order . (FOD #300.1)
Agr
eed Lump Sum Price: $ 15,801.48
9) TE
MPORARY ELEVATOR AT BUILDING 2
Ins
tallation of temporary elevator set up and operation associated with Building 2 permanent elevator approvals and building occupancy. Change includes all associated jurisdictional approvals for elevator, equipment set up and operation for clients move in activities and building occupancy – PCO 353. The critical path schedule is currently being evaluated; any potential delays will be part of a future contract change order. (FOD #310)
Agr
eed Lump Sum Price: $ 333,383.32
10) EL
EVATOR LOBBY CEILING MODIFICATIONS IN BUILDING 1
Ref
rame, rough in new electrical, install new lighting, hang, tape and paint on the 4th floor – PCO 95. The critical path schedule is currently being evaluated; any potential delays will be part of a future contract change order. (FOD #317)
Agr
eed Lump Sum Price: $ 14,646.58
11) SA
NITARY NAPKIN DISPENSER INFILL IN BUILDINGS 1 & 2
Demo ex
isting sanitary napkin dispenser, infill frame, hang, tape, and paint in Building 1 Room 306 and Building 2 Rooms 306 and 506 – PCO 368. The critical path schedule is currently being evaluated; any potential delays will be part of a future contract change order. (FOD #318) Agr
eed Lump Sum Price: $ 9,005.14

ATTACHMENT D
CITY OF STOCKTON Page 4 of 4
August 13, 2025
Fully Executed Form Routing: Original to City Clerk; Copy to Vendor 12) ADDIT
IONAL EXIT LIGHTING IN BUILDING 2
Ins
tall two additional exit egress light fixtures in Room 124 as confirmed as needed in RFI 372 and PCO 372. The critical path schedule is currently being evaluated; any potential delays will be part of a future contract change order. (FOD #324)
Agr
eed Lump Sum Price: $ 2,267.72
13) ADDE
D ACCESS DOOR IN BUILDING 1 LOBBY CEILING
Fr
ame new opening and install new 18” x 18” access door then repair drywall and paint in Room 102 – PCO 362. The critical path schedule is currently being evaluated; any potential delays will be part of a future contract change order. (FOD #327)
Agr
eed Lump Sum Price: $ 1,282.52
TO
TAL COST OF CHANGE ORDER WORK: $ 496,820.18
The additional compensation, if any, included in this change order constitutes full compensation, including all mark-ups, profits, surcharges, taxes and overhead costs, for the change in work as specified.

ATTACHMENT D
Updated 12/26/24
Vendor: Date: 05/12/25
Dept: Contract/PO Number: 422000787
Account # Requestor: Joshua Lewis
42,348,123.00$
05/03/22
Original Contract Council Approval Date: 05/03/22
05/03/26
57,076,260.46$
14,728,137.46$
Effective Date: Dec 2, 2021
CM Authority: $ 100,000 05/03/26

D M WD CM CC
CURRENT BALANCES OF CCOs
Last Council Action 11,980,575.41$ 12/03/24 54,328,698.41$ 5, 532,869.84$ Total approved CCOs since last Council Action 2,250,741.87$ 56,579,440.28$ 3,282,127.97$ NEW PROPOSED CCOs
56,579,440.28$ 5,532,869.84$
26 Additional Items 496,820.18$ 0 0 0 Y 57,076,260.46$ 2, 785,307.79$ Current CCO amount 496,820.18$
PREVIOUSLY APPROVED CCOs
Original Contract Y 05/03/22 42,348,123.00$
1 Additional Items 30,987.91$ 0 0 0 Y 42,379,110.91$
2 Additional Items 900,735.25$ 0 0 0 Y 43,279,846.16$
3 Additional Items 1,444,694.70$ 0 0 0 Y 44,724,540.86$ 4 Additional Items 885,511.92$ 0 0 0 Y 45,610,052.78$
5 Additional Items 241,668.98$ 0 0 0 Y 45,851,721.76$
6 Additional Items 796,418.83$ 0 0 0 Y 46,648,140.59$
7 Additional Items 93,261.41$ 0 0 0 Y 12/12/23 46,741,402.00$ 8 Additional Items 498,428.21$ 0 0 0 Y 47,239,830.21$
9 Additional Items 579,143.98$ 0 0 0 Y 47,818,974.19$
10 Additional Items 600,655.64$ 0 0 0 Y 48,419,629.83$ 11 Additional Items 753,685.27$ 0 0 0 Y 49,173,315.10$ 12 Additional Items 564,515.96$ 0 0 0 Y 49,737,831.06$ 13 Additional Items 282,350.14$ 0 0 0 Y 50,020,181.20$ 14 Additional Items 386,338.67$ 0 0 0 Y 50,406,519.87$ 15 Additional Items 331,771.29$ 0 0 0 Y 50,738,291.16$ 16 Additional Items 536,117.25$ 0 0 0 Y 51,274,408.41$ 17 Additional Items 300,000.00$ 0 0 0 Y 11/12/24 51,574,408.41$ 18 General Condition Delays 2,754,290.00$ 0 0 0 Y 12/03/24 54,328,698.41$ 19 Additional Items 149,817.27$ 0 0 0 Y 54,478,515.68$ 20 Additional Items 271,328.18$ 0 0 0 Y 54,749,843.86$ 21 Additional Items 263,744.49$ 0 0 0 Y 55,013,588.35$ 22 Additional Items 404,729.21$ 0 0 0 Y 55,418,317.56$ 23 Additional Items 533,691.14$ 0 0 0 Y 55,952,008.70$ 24 Additional Items 137,961.06$ 0 0 0 Y 56,089,969.76$ 25 Additional Items 489,470.52$ 0 0 0 Y 56, 579,440.28$ Previous CCO Amount -----> 14,231,317.28$ 12/3/2024 54,328,698.41$ Total CCO Amount and Time Extension To-Date -----> 14,728,137.46$

CHANGE ORDER CALCULATOR
New City Hall Renovations and Relocation
Public Works
E016015 / 4510-000-800007-300-000-30-45-000-000-

ENTRIES IN BOLD RED INDICATE
YOUR BALANCE OF CM AUTHORITY CCO AMOUNT IS EXCEEDED.

YOU MUST GO TO COUNCIL FOR APPROVAL.

Original Contract Amount:

Original Contract Award Date:

Original Contract Expiration Date:

Contract Amount to date:

Authorized CCO Amount to date:

Contract Expiration to date:

CCO No. Description
Requested
CCO Amount
Time
Extensions Revised
Contract Amount
Revised
CCO Authority Balance
Required
Approval
by:

Date CC
Approved
(mm/dd/yy)

ATTACHMENT D
City of Stockton
Legislation Text
File #: 25-0928, Version: 1

ADOPT RESOLUTION TO AUTHORIZE THE SAFE ROUTES TO SCHOOL SIDEWALK GAP CLOSURE - PHASE 1 PROJECT

RECOMMENDATION
It is recommended that the City Council adopt a resolution to:

1. Appropriate federal Surface Transportation Block Grant Program funds in the amount of $1,677,428 to the Safe Routes to School Sidewalk Gap Closure - Phase 1, Project No.

WT19013/Federal Project No. ATPSB1L-5008(187).

2. Appropriate Community Development Block Grant funds in the amount of $500,000 to the Safe Routes to School Sidewalk Gap Closure - Phase 1, Project No. WT19013/Federal Project No. ATPSB1L-5008(187).

3. Approve the plans and specifications for the Safe Routes to School Sidewalk Gap Closure - Phase 1, Project No. WT19013/Federal Project No. ATPSB1L-5008(187).

4. Award a Construction Contract in the amount of $2,109,395 to FBD Vanguard Construction, Inc. of Livermore, CA, for the Safe Routes to School Sidewalk Gap Closure - Phase 1, Project No. WT19013/Federal Project No. ATPSB1L-5008(187).

It is also recommended that the City Manager be authorized to take appropriate and necessary actions to carry out the purpose and intent of this resolution.

Summary
The Safe Routes to School Sidewalk Gap Closure - Phase 1 project is funded by federal Active Transportation Program (ATP), federal Surface Transportation Block Grant (STBG) Program, and federal Community Development Block Grant (CDBG) funds. The project will install curbs, gutters, sidewalks, curb ramps, and high visibility crosswalks at four school locations across Stockton - Sierra Nevada Middle School, Victory Elementary, Jane Frederick High School, and Montezuma Elementary School (Attachment A).

On August 28, 2025, the City received eight bids for this project. It is recommended that Council award a Construction Contract to the lowest bidder, FBD Vanguard Construction, Inc., in the amount of $2,109,395. It is also recommended that Council adopt a resolution approving the plans and specifications, and appropriating funds for the project. Construction is anticipated to be completed by the end of 2026.

City of Stockton Printed on 10/30/2025Page 1 of 4
powered by Legistar™
File #: 25-0928, Version: 1

DISCUSSION
Background
The Safe Routes to School Sidewalk Gap Closure - Phase 1 project is funded by federal ATP, federal STBG program, and federal CDBG funds. The project will install curbs, gutters, sidewalks, curb ramps, and high visibility crosswalks at four school locations across Stockton. The purpose of the project is to provide safer routes for children to walk to and from school by installing sidewalks where they do not exist today and other improvements that enhance pedestrian safety. The project locations are Sierra Nevada Middle School, Victory Elementary, Jane Frederick High School, and Montezuma Elementary School. The project originally included a fifth school location, Fillmore Elementary School. Due to extensive design, right-of-way acquisition, and utility relocations needed at this location, it will be completed as a separate Phase 2 project. All ATP funds for the project will be spent on Phase 1 construction costs. Phase 2 will be constructed using a combination of local and federal funds.

On December 15, 2020, by Resolution No. 2020-12-15-1108, Council approved the filing of Notice of Exemption No. NOE27-20.

On June 18, 2024, by Resolution No. 2024-06-18-1214, Council awarded a Professional Services Contract in the amount of $389,959 to R.E.Y. Engineers, Inc. of Folsom, CA, for design of the Safe Routes to School Sidewalk Gap Closure - Phase 1, Project No. WT19013/Federal Project No.

ATPSB1L-5008(187). Phase 1 design for improvements at Sierra Nevada Middle School, Victory Elementary, Jane Frederick High School, and Montezuma Elementary School was completed and funds were allocated by the California Transportation Commission at their March 2025 meeting. This allowed Phase 1 of the project to move forward to construction.

A Disadvantaged Business Enterprise (DBE) is a socially and economically disadvantaged small business owned by a woman or by a specified ethnic group that has been properly certified by Caltrans. These groups include:
· African American
· Asian Pacific American
· Native American
· Women
· Hispanic American
· Subcontinent Asian American
A DBE goal of 22.3 percent was established for this project. A pre-bid meeting was held on August 14, 2025, to emphasize the DBE requirements and to provide information on how to meet the project DBE goal. Bids were subsequently received for the project on August 28, 2025. However, on October 3, 2025, the U.S Department of Transportation published an Interim Final Rule amending regulations for the DBE program. The DBE Interim Final Rule stipulated that any contract awarded on or after October 3, 2025, must not have a DBE goal nor include DBE goal compliance requirements.

Accordingly, the recommended contract award has no weight or consideration of any DBE goals.

City of Stockton Printed on 10/30/2025Page 2 of 4
powered by Legistar™
File #: 25-0928, Version: 1
On July 26, 2016, Council adopted a Community Workforce and Training Agreement (CWTA). The CWTA became effective August 25, 2016, and applies to all Public Works projects over $1 million that are bid after that date. On July 16, 2019, by Motion No. 2019-07-16-1403, Council extended the CWTA term to August 25, 2024. On August 20, 2024, by Motion No. 2024-08-20-1203, Council extended the CWTA term to August 25, 2029. The CWTA was not applied to this project as federal regulations prohibit the use of such agreements.

Present Situation
On July 18, 2025, the Safe Routes to School Sidewalk Gap Closure - Phase 1, Project No.

WT19013/Federal Project No. ATPSB1L-5008(187), was advertised for bids. On August 28, 2025, eight bids were received with the following results:

COMPANY NAME BID AMOUNT
FBD Vanguard Construction, Inc. (Livermore, CA) $2,109,395.00 DSS Company dba Knife River Construction (Stockton, CA) $2,375,388.00 Zara Construction, Inc. (Sacramento, CA) $2,479,140.00
George Reed, Inc. (Stockton, CA) $2,490,856.00
B&M Builders, Inc. (Woodland, CA) $2,525,604.00
United Pavement Maintenance, Inc. (Hughson, CA) $2,687,152.50 JPB Designs, Inc. (Orangevale, CA) $2,696,512.00
Dirt Dynasty, Inc. (Farmington, CA) $2,714,974.35
Engineer's Estimate $2,610,149.00
Federal funding programs prohibit the use of Stockton Municipal Code (SMC) section 3.68.090, Local Business Preference, and Local Employment Ordinance, SMC section 3.68.095.

The bid from FBD Vanguard Construction, Inc. is the lowest bidder and has the proper license to perform the work. It is recommended that Council approve the plans and specifications, and award a Construction Contract to FBD Vanguard Construction, Inc. of Livermore, CA, in the amount of $2,109,395, for the Safe Routes to School Sidewalk Gap Closure - Phase 1, Project No.

WT19013/Federal Project No. ATPSB1L-5008(187). Construction is anticipated to be completed by the end of 2026.

FINANCIAL SUMMARY
With the appropriation of federal STBG Program funds in the amount of $1,677,428 and federal CDBG funds in the amount of $500,000 to the Safe Routes to School Sidewalk Gap Closure - Phase 1, Project No. WT19013/Federal Project No. ATBSB1L-5008(187), there will be sufficient funds to City of Stockton Printed on 10/30/2025Page 3 of 4
powered by Legistar™
File #: 25-0928, Version: 1
award a Construction Contract to FBD Vanguard Construction, Inc. in the amount of $2,109,395.

There is no impact to the City’s General Fund or any other unrestricted fund as a result of taking the recommended actions.

Attachment A - Vicinity Map
City of Stockton Printed on 10/30/2025Page 4 of 4
powered by Legistar™

DAVIS ROAD

THORNTON ROAD

PACIFIC AVENUE

HAMMER LANE

WILSON WAY

CHEROKEE ROAD

FREMONT STREETWILSON WAY

WEBER AVE

MARIPOSA RD

CALAVERAS RIVER

CALAVERAS RIVER

UPRR (SPRR)

CENTER STREET
W. ROSE ST.

FARMINGTON ROAD
2 1 4
3 CITY OF STOCKTON

DEPARTMENT OF PUBLIC WORKS

ATTACHMENT A
SAFE ROUTES TO SCHOOL SIDEWALK GAP CLOSURE - PHASE 1
352-(&712:7
FEDERAL PROJECT NO.

ATPSB1L-5008(187)

PROJECT LIMITS

VICINITY MAP
Resolution No.

STOCKTON CITY COUNCIL

RESOLUTION APPROPRIATING FUNDS, APPROVING THE PLANS AND

SPECIFICATIONS, AND AWARDING A CONSTRUCTION CONTRACT FOR THE SAFE ROUTES TO SCHOOL SIDEWALK GAP CLOSURE - PHASE 1, PROJECT NO.

WT19013/FEDERAL PROJECT NO. ATPSB1L-5008(187)

On August 28, 2025, the City Clerk of the City of Stockton opened, examined, and publicly declar ed the sealed proposals or bids offered for the Safe Routes to School Sidewalk Gap Closure - Phase 1, Project No. WT19013/Federal Project No. ATPSB1L - 5008(187); and

The project will install curb s, gutters, sidewalk s, curb ramps, and high visibility crosswalks at four school locations across Stockton - Sierra Nevada Middle School, Victory Elementary, Jane Frederick High School, and Montezuma Elementary School; and

FBD Vanguard Construction, Inc. is the lowest bidder in the amount of $2,109,395.00; now, therefore,

BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF STOCKTON, AS FOLLOWS:

1. The City Council authorizes the appropriation of federal Surface Transportation Block Grant Program funds in the amount of $1,6 77,428 to the Safe Routes to School Sidewalk Gap Closure - Phase 1, Project No. WT19013/Federal Project No. ATPSB1L-5008(187).

2. The City Council authorizes the a ppropriation of Community Development Block Grant funds in the amount of $500,000 to the Safe Routes to School Sidewalk Gap Closure - Phase 1, Project No. WT19013/Federal Project No. ATPSB1L-5008(187).

3. The City Council approves the plans and specifications for the Safe Routes to School Sidewalk Gap Closure - Phase 1, Project No. WT19013/Federal Project No.

ATPSB1L-5008(187).

4. The City Council awards a Construction Contract between the City of Stockton and FBD Vanguard Construction, Inc., in the amount of $2,109,395.00, and the City Manager is authorized and directed to execute same, a copy of which is attached as Exhibit 1 and incorporated by this reference.

//

5. The City Manager is hereby authorized to take whatever actions are necessary and appropriate to carry out the purpose and intent of this Resolution.

PASSED, APPROVED, and ADOPTED November 4, 2025 .

CHRISTINA FUGAZI
Mayor of the City of Stockton
ATTEST:

KATHERINE ROLAND, CMC, CPMC
City Clerk of the City of Stockton
F
ederal Construction Contract – FBD VANGUARD CONSTRUCTION, INC. – SAFE ROUTES TO SCHOOL SIDEWALK GAP CLOSURE – PHASE I, PROJECT NO. WT19013 / FEDERAL PROJECT NO. ATPSB1L-5008(187) (Updated 10/18/23)

CONSTRUCTION CONTRACT
This contract is made and entered into on _____________, by and between FBD VANGUARD CONSTRUCTION, INC. , a STATE OF CALIFORNIA CORPORATION, with a business address at 550 GREENVILLE ROAD. LIVERMORE, CA 94550, hereinafter called "CONTRACTOR," and CITY OF STOCKTON, a municipal corporation, hereinafter called "CITY."
W I T N E S S E T H:

WHEREAS, plans and specifications for the construction of SAFE ROUTES TO SCHOOL SIDEWALK GAP CLOSURE – PHASE I, PROJECT NO. WT19013/FEDERAL PROJECT NO. ATPSB1L-5008(187) , hereinafter called “PROJECT,” were regularly adopted by Council Resolution No. 2025-11-04-0928, on November 4, 2025; and WHEREAS, the contract for said work was regularly awarded to CONTRACTOR, by Council Resolution No. 2025-11-04-0928, on November 4, 2025.

NOW, THEREFORE, in consideration of the promises and of the mutual covenants herein contained, the parties hereto expressly agree as follows:

CONTRACTOR agrees:

1. SCOPE OF SERVICES. To do the work and furnish all the labor, materials, tools, equipment, and insurance required for the construction of PROJECT in accordance with the plans and specifications adopted on November 4, 2025, by Council Resolution No. 2025-11-04-0928. The "contract documents," which include the bid documents, project plans, specifications, all letters of clarification, and the City of Stockton Standard Specifications and Plans, are incorporated into and made a part of this contract by this reference to the same extent as if fully set forth.

2. COMPENSATION. To do and perform the work contemplated hereby in a good and workmanlike manner and to furnish all labor, materials, tools, and equipment necessary therefore at the prices specified in Exhibit A, attached hereto and by reference made a part hereof, under the direction of and to the complete satisfaction of the Director of Public Works of the City of Stockton. Total compensation for services and reimbursement for costs shall not exceed $2,109,395.00, or as otherwise mutually agreed to in a Contract Change Order.

3. INSURANCE. CONTRACTOR shall not commence any work before obtaining, and shall maintain in force at all times during the duration and performance of this contract, the policies of insurance specified in Exhibit B, which is attached to this contract and incorporated by this reference, and as provided in the “contract documents” including Section 7-1.06 of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, by Council Resolution No. 2016-09-27-1213, effective

EXHIBIT 1

Federal Construction Contract – FBD VANGUARD CONSTRUCTION, INC. – SAFE ROUTES TO SCHOOL SIDEWALK GAP CLOSURE – PHASE I, PROJECT NO. WT19013 / FEDERAL PROJECT NO. ATPSB1L-5008(187) (Updated 10/18/23) September 27, 2016.

It shall be a requirement under this Agreement that any available insurance proceeds broader than or in excess of the specified minimum Insurance coverage requirements and/or limits shall be available to the Additional Insured.

Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any Insurance policy or proceeds available to the named Insured; whichever is greater.

The Additional Insured coverage under the Contractor’s policy shall be “primary and non- contributory” and will not seek contribution from the City of Stockton’s insurance or self - insurance and shall be at least as broad as CG 20 01 04 13.

The limits of insurance required in this A greement may be satisfied by a combination of primary and umbrella or excess insurance. Any umbrella or excess Insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis for the benefit of the City of Stockton (if agreed to in a written contract or A greement) before the City of Stockton’s own insurance or self - insurance shall be called upon to protect it as a named insured.

All self-insured retentions (SIR) must be disclosed to Risk Management for approval and shall not reduce the limits of liability. Payment Bond in the amount of the self -insured retention (SIR) may be required.

Policies containing any self-insured retention (SIR) provision shall provide or be endorsed to provide that the SIR may be satisfied by either the named Insured or the City of Stockton.

The City of Stockton reserves the right to obtain a full certified copy of any Insurance policy and endorsements.

Failure to exercise this right shall not constitute a waiver of right to exercise later.

Contractor shall maintain insurance as required by this contract to the fullest amount allowed by law and shall maintain insurance for a minimum of five years following the completion of this project. In the event contractor fails to obtain or maintain co mpleted operations coverage as required by this Agreement, the City at its sole discretion may purchase the coverage required and the cost will be paid by contractor.

Contractor agrees to include with all S ubcontractors in their subcontract the same requirements and provisions of this A greement including the indemnity and insurance requirements to the extent they apply to the scope of the Subcontractor’s work.

Subcontractors hired by Contractor agree to be bound to Contractor and the City of

EXHIBIT 1

Federal Construction Contract – FBD VANGUARD CONSTRUCTION, INC. – SAFE ROUTES TO SCHOOL SIDEWALK GAP CLOSURE – PHASE I, PROJECT NO. WT19013 / FEDERAL PROJECT NO. ATPSB1L-5008(187) (Updated 10/18/23) Stockton in the same manner and to the same extent as Contractor is bound to the City of Stockton under the Contract Documents. Subcontractor further agrees to include these same provisions with any Sub- subcontractor. A copy of the City of Stockton Contract Document Indemnity and Insurance provisions will be furnished to the Subcontractor upon request. The General Contractor shall require all sub-contractors to provide a valid certificate of insurance and the required endorsements included in the Agreement prior to commencement of any work and contractor will provide proof of compliance to the City.

4. INDEMNITY AND HOLD HARMLESS. To the fullest extent permitted by law, Contractor shall hold harmless, defend, and indemnify City of Stockton and its officers, officials, employees, and volunteers from and against all claims, damages, losses, and expenses including attorney fees arising out of the performance of the work described herein, caused in whole or in part by any negligent act or omission of the Contractor, any subcontractor, anyone directly or indirectly employed by any of them, or anyone for whose acts any of them may be liable, except where caused by the active negligence, sole negligence, or willful misconduct of the City of Stockton. This obligation is independent of, and shall not in any way be limited by, the minimum Insurance obligations contained in this agreement. These obligations shall survive the completion or termination of this agreement.

5. STANDARD PLANS AND SPECIFICATIONS. The performance of said work and the furnishing of said materials shall be executed in accordance with Section 8-

1.04B of the City of Stockton Standard Specifications and Plans as adopted on September 27, 2016, b y Council Resolution No. 2016- 09-27-1213, effective September 27, 2016, and the provisions of the issued project specifications.

The Director of Public Works will furnish CONTRACTOR a weekly statement showing the number of days charged to the contract for the preceding week, the number of days specified for completion of the contract, and the number of days remaining to complete the contract. CONTRACTOR will be allowed one (1) week in which to file a written protest setting forth in what respects said weekly statement is incorrect, otherwise the statement shall be deemed to have been accepted by CONTRACTOR as correct.

6. WORKING DAYS. It is agreed by the parties to the contract that in case all the work called for under the contract in all parts and requirements, is not finished or completed within the number of days as set forth, damage will be sustained by CITY, and that it is and will be impracticable and extremely difficult to ascertain the actual damage which CITY will sustain in the event of and by reason of such delay; and it is therefore agreed that CONTRACTOR will pay to CITY the sum of SIX THOUSAND EIGHT HUNDRED AND NO/100 DOLLARS ($6,800.00) per day for each and every calendar day's delay in finishing the work in excess of the number of days prescribed; and CONTRACTOR agrees to pay said liquidated damages as herein provided, and in case the same are not paid, agrees that CITY, may deduct the amount thereof from any monies due or that may become due CONTRACTOR under the contract.

EXHIBIT 1

Federal Construction Contract – FBD VANGUARD CONSTRUCTION, INC. – SAFE ROUTES TO SCHOOL SIDEWALK GAP CLOSURE – PHASE I, PROJECT NO. WT19013 / FEDERAL PROJECT NO. ATPSB1L-5008(187) (Updated 10/18/23) It is further agreed that in case the work called for under the contract is not finished and completed in all parts and requirements within the number of days as specified, CITY shall have the right to increase the number of days or not, as may seem best to serve the interest of CITY, and if CITY decides to increase the said number of days, CITY shall further have the right to charge to CONTRACTOR, CONTRACTOR's heirs, assigns or sureties, and to deduct from the final payment for the work, all or any part, as may be deemed proper, the liquidated damages as specified or the actual cost of engineering, inspection, superintendence, and other overhead expenses which are directly chargeable to the contract, and which accrue during the period of such extension, whichever is greater, except the cost of final surveys and preparation of final estimate shall not be included in such charges.

A working day shall not include, nor shall CONTRACTOR be assessed with liquidated damages nor the additional cost of engineering and inspection during any delay beyond the time named for the completion of the work caused by acts of God or of the public enemy, acts of CITY, fire, floods, epidemics, quarantine restrictions, strikes, and freight embargoes and subject to approval by the Director, inability to get materials ordered by CONTRACTOR or Subcontractor due to such causes provided that CONTRACTOR shall notify the Director in writing of the causes of delay within five (5) working days from the beginning of any such delay, and the Director shall ascertain the facts and the extent of the delay, and Director's findings of the facts thereon shall be final and conclusive.

If CONTRACTOR is delayed by reason of alterations made in these specifications, or by any act of the Director or of CITY, not contemplated by the contract, the time of completion shall be extended proportionately, and CONTRACTOR shall be relieved during the period of such extension of any claim for liquidated damages, engineering or inspection charges or other penalties. CONTRACTOR shall have no claim for any other compensation for any such delay.

7. CONFORMANCE TO APPLICABLE LAWS

A. TITLE VI

Title VI of the Civil Rights Act of 1964 requires that “no person in the United States shall, on the grounds of race, color, or national origin, be excluded from participation in, be denied the benefits of, or be subjected to discrimination under any program or activity receiving federal financial assistance.” (42 USC Section 2000d)
http://www.dol.gov/oasam/regs/statutes/titlevi.htm.

The City of Stockton requires compliance with the requirements of Title VI in all of its programs and activities regardless of funding source.

EXHIBIT 1

Federal Construction Contract – FBD VANGUARD CONSTRUCTION, INC. – SAFE ROUTES TO SCHOOL SIDEWALK GAP CLOSURE – PHASE I, PROJECT NO. WT19013 / FEDERAL PROJECT NO. ATPSB1L-5008(187) (Updated 10/18/23) B. DISCRIMINATION AND HARASSMENT POLICY

The City of Stockton has a Discrimination and Harassment Policy (Exhibit C). The purpose of this policy is to reaffirm the CITY’s commitment to demonstrating respect for all individuals by strictly prohibiting discrimination and harassment, including sexual harassment in the workplace, to define the types of behavior and conduct prohi bited by this policy, and to set forth a procedure for reporting, investigating, and resolving complaints of discrimination and harassment in the workplace.

C. LABOR STANDARDS AND PROVISIONS/CALIFORNIA LABOR CODE

The bidder shall understand that conditions set forth in Chapter 1, Part 7, Division 2 of the California Labor Code shall be considered part of the contract agreement.

https://leginfo.legislature.ca.gov/faces/codes_displayText.xhtml?lawCode =LAB&division=2.&title=&part=7.&chapter=1.&article=2.

D. PREVAILING WAGE

CONTRACTOR and any Subcontractor shall pay each employee engaged in the trade or occupation not less than the prevailing hourly wage rate. In accordance with the provisions of Section 1770 of the Labor Code, the Director of Department of Industrial Relations of the State of California has determined the general prevailing rates of wages and employer payments for health and welfare, pension, vacation, travel time, and subsistence pay as provided for in Section 1773.1, apprenticeship or other training programs authorized by Section 3093 and similar purposes applicable to the work to be done. CONTRACTOR performing the work under this contract shall obtain a copy of the wage rate determination and shall distribute copies to each Subcontractor (see Exhibit D). As the wage determination for each craft reflects an expiration date, it shall be the prime CONTRACTOR and each Subcontractor's responsibility to ensure that the prevailing wage rates of concern is current and paid to the employee.

(i) The CONTRACTOR performing the work shall be responsible for obtaining a copy of the State wage rate determination. State wage rates may be obtained at
http://www.dir.ca.gov/OPRL/pwd/Determinations/Northern/Northern. pdf. The CONTRACTOR shall be responsible for posting said wage rates at a prominent location at the work site and shall maintain same in a good readable condition for the duration of the work.

EXHIBIT 1

Federal Construction Contract – FBD VANGUARD CONSTRUCTION, INC. – SAFE ROUTES TO SCHOOL SIDEWALK GAP CLOSURE – PHASE I, PROJECT NO. WT19013 / FEDERAL PROJECT NO. ATPSB1L-5008(187) (Updated 10/18/23) (ii) Should the CONTRACTOR choose to work on a Saturday, Sunday or on a holiday recognized by the Labor Unions, the CONTRACTOR shall reimburse the CITY the actual cost of engineering, inspection, superintendence, and/or other overhead expenses which are directly chargeable to the contract. Should such work be undertaken at the request of the CITY, reimbursement will not be required. To conform strictly with the provisions of Division 2, Part 7, Chapter 1, Article 2, of the Labor Code of the State of California. To forfeit as a penalty to CITY the sum of TWENTY-FIVE AND NO/100 DOLLARS ($25.00) for each laborer, worker, or mechanic employed by CONTRACTOR, or by any Subcontractor under CONTRACTOR, in the execution of t his contract, for each calendar day during which any laborer, worker, or mechanic is required or permitted to work more than eight (8) hours and who is not paid the general prevailing rate of per diem wages for holiday and overtime work in violation of the provisions of Sections 1770 to 1781 of the Labor Code of the State of California. That all sums forfeited under the provisions of the foregoing sections shall be deducted from the payments to be made under the terms of this contract.

(iii) The CONTRACTOR to whom the contract is awarded shall ensure that the prime and each subcontractor will in accordance with Section 1776 of the Labor Code, maintain certified payroll records. A copy of said records shall be provided with each invoice to the Public Works Department, Attention Contract Compliance Officer. It shall be the CONTRACTOR’S responsibility to obtain copies of the current prevailing wage rate determination for all subcontractors. Additionally, certified payroll records must be uploaded to the DIR website as required by labor code.

(iv) The CONTRACTOR shall comply with the provisions established in Section 1777.5 of the Labor Code concerning the 1) certified approval by local joint apprenticeship committees for the employment and training of apprentices, and 2) contribution of funds to administer and conduct apprenticeship programs, if applicable to the job.

E. APPENDIX E OF THE TITLE VI ASSURANCES

During the performance of this contract, the contractor, for itself, its assignees, and successors in interest agrees to comply with the Appendix E of the Title VI Assurances attached as Exhibit F.

EXHIBIT 1

Federal Construction Contract – FBD VANGUARD CONSTRUCTION, INC. – SAFE ROUTES TO SCHOOL SIDEWALK GAP CLOSURE – PHASE I, PROJECT NO. WT19013 / FEDERAL PROJECT NO. ATPSB1L-5008(187) (Updated 10/18/23) F. SANCTIONS
Deliverables must conform with all applicable federal, state, and local laws.

Such conformity includes compliance with federal sanctions, and Contractor certifies that it has not and will not engage in prohibited transactions with sanctioned persons or entities.

CITY agrees:

8. COMPENSATION. To pay CONTRACTOR for the work herein
contemplated in the following manner: Progress payments will be made on or about the first day of each calendar month, in such sum as shall make the aggregate of payment up to such day equal to ninety-five percent (95%) of the proportional contract price, upon the basis of the progress certificate of the Director of Public Works as to the amount of work done and the proportional amount of the contract price represented therefor e; and all of the remaining part of the contract price not as aforesaid paid, shall be paid at the expiration of thirty-five (35) days from the completion of said work of construction and the certification by the Director of Public Works of such completion.

9. SECURITIES. Pursuant to Section 22300 of the Public Contract Code, CONTRACTOR will be permitted, at its request and sole expense, to substitute securities for any monies withheld by the CITY to ensure performance under the contract. Said securities will be deposited either with the CITY or with a State or federally chartered bank as escrow agent. Securities eligible for this substitution are those listed in Section 16430 of the California Government Code or bank or savings and loan certificates of depos it.

CONTRACTOR shall be the beneficial owner of any securities substituted for monies withheld and shall receive any interest thereon.

10. CHANGE ORDERS . CITY reserves the right to make such alterations, deviations, additions to or omissions from the plans and specifications, including the right to increase or decrease the quantity of any item or portion of the work, as may be deemed by the Engineer to be necessary or advisable and to require such extra work as may be determined by the Engineer to be required for the proper completion or construction of the whole work contemplated.

Any such changes will be set forth in a contract change order which will specify, in addition to the work done in connection with the change made, adjustment of contract time, if any, and the basis of compensation for such work. A contract change order wi ll not become effective until approved by the City Manager and/or the City Council.

Processing of change orders shall be in accordance with Section 4- 1.05A of the City of Stockton Standard Specifications and Plans as adopted by Council on September 27, 2016, by Resolution No. 2016-09-27-2013, effective September 27, 2016, or as otherwise amended by Council. When the compensation for an item of work is subject to adjustment under the provisions of Standard Specifications and Plans, Section 4- 1.05A,

EXHIBIT 1

Federal Construction Contract – FBD VANGUARD CONSTRUCTION, INC. – SAFE ROUTES TO SCHOOL SIDEWALK GAP CLOSURE – PHASE I, PROJECT NO. WT19013 / FEDERAL PROJECT NO. ATPSB1L-5008(187) (Updated 10/18/23) CONTRACTOR shall, upon request, promptly furnish the Engineer with adequate detailed cost data for such item of work.

11. AUDITS
(a) CITY reserves the right to periodically audit all charges made by CONTRACTOR to CITY for services under the contract. Upon request, CONTRACTOR agrees to furnish CITY, or a designated representative, with necessary information and assistance.

(b) CONTRACTOR agrees that CITY or its delegate will have the right to review, obtain and copy all records pertaining to performance of the contract.

CONTRACTOR agrees to provide CITY or its delegate with any relevant information requested and shall permit CITY or its delegate access to its premises, upon reasonable notice, during normal business hours for the purpose of interviewing employees and inspecting and copying such books, records, accounts, and other material that may be relevant to a matter under investigation for the purpose of determining compliance with this requirement. CONTRACTOR further agrees to maintain such records for a period of five (5) years after final payment under the contract.

12. FHWA 1273 AND CARGO PREFERENCE ACT
Federal form FHWA 1273 is physically included in this contract as Exhibit E.

In compliance with the Cargo Preference Act of 1954 (CPA), 46 CFR §381, and the implementing regulations in 46 CFR §381.7, the Contractor agrees:

A. To utilize privately owned United States-flag commercial vessels to ship at least 50 percent of the gross tonnage (computed separately for dry bulk carriers, dry cargo liners, and tankers) involved, whenever shipping any equipment, material, or commodities pursuant to this contract, to the extent such vessels are available at fair and reasonable rates for United States - flag commercial vessels;

B. To furnish within 20 days following the date of loading for shipments originating within the United States or within 30 working days following the date of loading for shipments originating outside the United States, a legible copy of a rated, “on- board” commercial ocean bill -of-lading in English for each shipment of cargo described in paragraph (b) (1) of this section to both the Contracting Officer (through the prime contractor in the case of subcontractor bills-of-lading) and to the Division of National Cargo, Office of Market Development, Maritime Administration, Washington, DC 20590;

C. To insert the substance of the provisions of this clause in all subcontracts issued pursuant to this contract.

EXHIBIT 1
EXHIBIT 1
Letter of Clarification No. 4 - Aui:iust 25, 2025
SAFE ROUTES TO SCHOOL SIDEWALK GAP CLOSURE - PHASE 1
PROJECT NO. WT19013 / FEDERAL PROJECT NO. ATPSB1L-5008{187)

BIDDING SCHEDULE
Each bidder shall bid each item, including all alternate bid(s). Failure to bid an item shall be just cause for considering the bid as non-responsive. Line-item costs should include all Contractor's overhead and profit and indirect costs. Bids not presented on City forms shall be cause for considering the bid as non-responsive. If the City awards the contract, the award is made
to the lowest responsible bidder.

ITEM NO. ITEM DESCRIPTION UNITS EST. UNIT TOTAL PRICE
QTY. PRICE
1 MOBILIZATION LS 1 qi/100
2 TRAFFIC CONTROL LS 1 '13, 70C)
3 WATER POLLUTION CONTROL LS 1 lb,ocx>
4 CONSTRUCTION STAKING AND MONUMENT LS 1 l{O,ooo PRESERVATION 5 CLEAR AND GRUB LS 1 b\010?0
6 REMOVE EXISTING ASPHALT PAVEMENT AND SF 10,304 8 AGGREGATE BASE 7 REMOVE EXISTING ASPHALT PAVEMENT 8-INCHES DEEP SF 6,573 � 8 REMOVE EXISTING CURB AND GUTTER LF 1,462 ri
9 REMOVE CONCRETE AND AGGREGATE BASE SF 8,462 \2
10 REMOVE EXISTING STRIPING LF 612 <?
11 REMOVE EXISTING MARKING SF 572 \Z.
12 ABANDON STORM DRAIN PIPE LS 1 �1$QO
13 REMOVE EXISTING STORM DRAIN PIPE LF 177 \C\\
14 REMOVE EXISTING DRAIN INLET EA 13 �-1.lOd
15 REMOVE ROADSIDE SIGN EA 2 }L'-\3
16 REMOVE EXISTING TREE EA 1 8,i.Joo
17 ADJUST UTILITY VAULT TO NEW GRADE EA 1 900
18 ADJUST TRAFFIC SIGNAL BOX TO NEW GRADE EA 1 300
19 ADJUST STORM DRAIN MAINTENANCE HOLE RIM TO EA 2 21 '6ad NEW GRADE 20 ADJUST SANITARY SEWER MAINTENANCE HOLE RIM TO EA 1 l-11160 NEW GRADE 21 ADJUST SANITARY SEWER LAMPHOLE RIM TO NEW EA 1
I i-:1, 1001 GRADE
Bid Forms Page 5 of 78 Last Revised 02/28/24

EXHIBIT A

EXHIBIT 1
ITEM NO. ITEM DESCRIPTION
22 REMOVE AND REINSTALL KEYSTONE WALL
23 RELOCATE RECTANGULAR RAPID FLASHING BEACON
24 RELOCATE ROADSIDE SIGN
25 RELOCATE BUS STOP SIGN
26 RELOCATE MAILBOX
27 ASPHALT CONCRETE
28 CLASS 2 AGGREGATE
BASE
29 VERTICAL CURB AND GUTTER (R-52, R-55)
30 VERTICAL CURB AND GUTTER TYPE 4
31 ROLL CURB AND GUTTER (R-53, R-55)
32 VERTICAL CURB
33 CONCRETE SIDEWALK
34 DETECTABLE WARNING SURFACE
35 RES IDENTIAL DRIVEWAY (R-58)
36 STANDA RD COMMERCIAL DRIVEWAY (R-59)
37 SPECIAL COMMERCIAL DRIVEWAY (R-57)
38 ROADWAY EXCAVATION
39 EXPO RT OF SOILS
40 STRIPI NG- DETAIL 27B
41 24-INCH WIDE WHITE
42 12-INCH WIDE YELLOW
43 24-INCH WIDE YELLOW
___ 44_ Wbll"fE.MARKINGS -�---··-···
45 MARK INGS- YIELD LINES
46 ROADSIDE SIGNS
47 PEDESTRIAN BARRICADE
48 UNDER SIDEWALK DRAIN (D-12)
49 8" DIP CL 350 SD PIPE
50 12" RCP CL Ill SD PIPE
51 12" RCP CL V SD PIPE
52 24" RCP CL V SD PIPE
Bid Forms Page 6 of 78
e er o an 1cat1on No. 4 - Au us L ti f Cl 'f • t 25 2025' UNITS EST. UNIT TOTAL PRICE
LS
EA
EA
EA
EA
TON
TON
LF
LF
LF
LF
SF
SF
EA
EA
EA
CY
CY
LF
LF
LF
LF
-SF'�
SF
EA
EA
LS
LF
LF
LF
LF
QTY ..
1 ,.
1 �· ,,.,
11 1
2 640
1,677
2,171
7 240
839
15,228
611
8 2
3 1,159
832
57 248
1,816
444
--2€l4 -
99 7
1 1
214
32 5
339
PRICE
g-�
·-�"- --
·r•i3,COO
t..\5'D.
'430.
430
4,25
�Q'·
L\3
So
L\S
a�-'"T�
cRGJ
�,�o
5,0C)()
5-tt>O
·'10
�6
q
d\ \
\()
2\
�tlJ-
to
6qo
·1,soo,
i{OO

9.-W
550
'DS'O
3LO
------- ---
Last Revised 02/28/24
-·

EXHIBIT A

EXHIBIT 1
ITEM NO. ITEM DESCRIPTION
53 36" RCP CL V SD PIPE
54 TYPE 1 CURB INLET (D-6)
55 JUNCTION BOX
56 CONNECT TO EXISTING STORM DRAIN PIPE OR

STRUCTURE
57 SHALLOW MAINTENANCE HOLE
58 TYPE 1 MAINTENANCE HOLE (D-5)
59 STORM DRAIN MESSAGE (D-10)
60 STORM DRAIN INLET (D-14A)
61 TYPE 2 CURB INLET (D-8)

TOTAL BID
Bid Forms Page 7 of 78
etter o an 1cat1on o. - U11Ust 2 , L f Cl 'f' • N 4 A 5 2025 UNITS EST. UNIT TOTAL PRICE
QTY. PRICE
LF 20 ,rio
EA 15 l"')t206
EA 1 13,W
EA 10 4,�
EA 1 l0,006
EA 7 -lb,(X)O
EA 26 ��L\
EA 4 i61 '-IOC
EA 4
..,, ao: 1 -- I .. -�
s 2-, roq 1 3 Cf s, 0 0
--- - ----- ··- -- - -- -- -
Last Revised 02/28/24

EXHIBIT A

EXHIBIT 1
SAFE ROUTES TO SCHOOL SIDEWALK GAP CLOSURE – PHASE 1
PROJECT NO. WT19013 / FEDERAL PROJECT NO. ATPSB1L-5008(187) Insu
rance Requirements
(Construction Contracts)
Contr
actor shall procure and maintain for the duration of the contract, and for five (5) years thereafter, insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his agents, representatives, employees, or subcontractors.

MINIMUM SCO

PE AND LIMIT OF INSURANCE
Cover
age shall be at least as broad as:

1. Comm
ercial General Liability (CGL): Insurance Services Office (ISO) Form CG 00 01 covering CGL on an “occurrence” basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $5,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit.

2. Auto
mobile Liability: Insurance Services Office Form CA 0001 covering Code 1 (any auto), with limits no less than $5,000,000 per accident for bodily injury and property damage.

3. Workers
’ Compensation insurance as required by the State of California, with Statutory Limits, and Employers’ Liability insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.

4. Suret
y Bonds as described below.

If the contractor maintains broader coverage and/or higher limits than the minimums shown above, the City of Stockton requires and shall be entitled to the broader coverage and/or the higher limits maintained by the contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City of Stockton.

Self -Insured Retentions
Self-insured retentions must be declared to and approved by the City of Stockton. The City of Stockton may require the Contractor to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention. The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the named insured or City of Stockton. The CGL and any policies, including Excess liability policies, may not be subject to a self-insured retention (SIR) or deductible that exceeds $25,000 unless approved in writing by City of Stockton. Any and all deductibles and SIRs shall be the sole responsibility of Contractor or

EXHIBIT B

EXHIBIT 1
subcontractor who procured such insurance and shall not apply to the Indemnified Additional Insured Parties. City of Stockton may deduct from any amounts otherwise due Contractor to fund the SIR/deductible. Policies shall NOT contain any self-insured retention (SIR) provision that limits the satisfaction of the SIR to the Named Insured.

The policy must also provide that Defense costs, including the Allocated Loss Adjustment Expenses, will satisfy the SIR or deductible. City of Stockton reserves the right to obtain a copy of any policies and endorsements for verification.

Other Insurance Provisions

The insurance policies are to contain, or be endorsed to contain, the following provisions:

1. The City of Stockton, its officers, officials, employees, and volunteers are to be covered as additional insureds on the CGL policy with respect to liability arising out of work or operations performed by or on behalf of the Contractor including materials, parts, or equipment furnished in connection with such work or operations and automobiles owned, leased, hired, or borrowed by or on behalf of the Contractor.

General liability coverage can be provided in the form of an endorsement to the Contractor’s insurance (at least as broad as ISO Form CG 20 10, CG 11 85 or both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 forms if later revisions used).

Additional insured Name of Organization shall read “City of Stockton, its officers, officials, employees, and volunteers.” Policy shall cover City of Stockton, its officers, officials, employees, and volunteers for all locations work is done under this contract.

2. For any claims related to this project, the Contractor’s insurance coverage shall be primary and non-contributory insurance coverage at least as broad as ISO CG 20 01 04 13 as respects the City of Stockton, its officers, officials, employees, and volunteers. Any insurance or self-insurance maintained by the City of Stockton, its officers, officials, employees, or volunteers shall be excess of the Contractor’s insurance and shall not contribute with it. This requirement shall also apply to any Excess or Umbrella liability policies. The City of Stockton does not accept endorsements limiting the Contractor’s insurance coverage to the sole negligence of the Named Insured.

3. Each insurance policy required by this clause shall provide that coverage shall not be canceled, except with notice to the City of Stockton.

Claims Made Policies (Professional & Pollution only)

If any coverage required is written on a claims-made coverage form:

1. The retroactive date must be shown, and this date must be before the execution date of the contract or the beginning of contract work.

2. Insurance must be maintained, and evidence of insurance must be provided for at least five (5) years after completion of contract work.

3. If coverage is cancelled or non-renewed and not replaced with another claims- made policy form with a retroactive date prior to the contract effective, or start of work

EXHIBIT B

EXHIBIT 1
date, the Contractor must purchase extended reporting period coverage for a minimum of five (5) years after completion of contract work.

4. A copy of the claims reporting requirements must be submitted to the City of Stockton for review.

5. If the services involve lead-based paint or asbestos identification/remediation, the Contractors Pollution Liability policy shall not contain lead-based paint or asbestos exclusions. If the services involve mold identification/remediation, the Contractors Pollution Liability policy shall not contain a mold exclusion, and the definition of Pollution shall include microbial matter, including mold.

Umbrella or Excess Policies
The Contractor may use Umbrella or Excess Policies to provide the liability limits as required in this agreement. This form of insurance will be acceptable provided that all of the Primary and Umbrella or Excess Policies shall provide all of the insurance coverages herein required, including, but not limited to, primary and non-contributory, additional insured, Self-Insured Retentions (SIRs), indemnity, and defense requirements. The Umbrella or Excess policies shall be provided on a true “following form” or broader coverage basis, with coverage at least as broad as provided on the underlying Commercial General Liability insurance. No insurance policies maintained by the Additional Insureds, whether primary or excess, and which also apply to a loss covered hereunder, shall be called upon to contribute to a loss until the Contractor’s primary and excess liability policies are exhausted.

Acceptability of Insurers
Insurance is to be placed with insurers authorized to conduct business in the state with a current A.M. Best rating of no less than A: VII, unless otherwise acceptable to the City of Stockton.

Waiver of Subrogation
Contractor hereby agrees to waive rights of subrogation which any insurer of Contractor may acquire from Contractor by virtue of the payment of any loss.

Contractor agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation. The Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of the City of Stockton for all work performed by the Contractor, its employees, agents and subcontractors.

Verification of Coverage
Contractor shall furnish the City of Stockton with original certificates and amendatory endorsements or copies of the applicable policy language affecting coverage required by this clause and a copy of the Declarations and Endorsements Pages of the CGL and any Excess policies listing all policy endorsements. All certificates and endorsements and copies of the Declarations & Endorsements pages are to be received and approved by the City of Stockton before work commences. However, failure to obtain the required documents prior to the work beginning shall not waive the Contractor’s obligation to provide them. The City of Stockton reserves the right to require complete, certified copies of all required insurance policies, including

EXHIBIT B

EXHIBIT 1
endorsements required by these specifications, at any time. City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances.

Subcontractors
Contractor shall require and verify that all subcontractors maintain insurance meeting all requirements stated herein, and Contractor shall ensure that City of Stockton is an additional insured on insurance required from subcontractors. For CGL coverage, subcontractors shall provide coverage with a form at least as broad as CG 20 38 04 13.

Duration of Coverage
CGL & Excess liability policies for any construction related work, including, but not limited to, maintenance, service, or repair work, shall continue coverage for a minimum of 5 years for Completed Operations liability coverage. Such Insurance must be maintained, and evidence of insurance must be provided for at least five (5) years after completion of the contract of work.

Surety Bonds
Contractor shall provide the following Surety Bonds:

1. Bid Bond

2. Performance Bond

3. Payment Bond

4. Maintenance Bond

The Payment Bond and the Performance Bond shall be in a sum equal to the contract price. If the Performance Bond provides for a one-year warranty a separate Maintenance Bond is not necessary. If the warranty period specified in the contract is for longer than one year a Maintenance Bond equal to 10% of the contract price is required. Bonds shall be duly executed by a responsible corporate surety, authorized to issue such bonds in the State of California and secured through an authorized agent with an office in California.

Special Risks or Circumstances
City of Stockton reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other circumstances.

Certificate Holder Address

The address for mailing certificates, endorsements and notices shall be:

City of Stockton
Its Officers, Officials, Employees and Volunteers
400 E Main Street, 3rd Floor – HR
Stockton, CA 95202

EXHIBIT B

EXHIBIT 1
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 1 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 I. PURPOSE
The purpose of this policy is to reaffirm the City's commitment to demonstrating respect for all individuals by strictly prohibiting discrimination and harassment, including sexual harassment in the workplace. This policy defines prohibited behavior and conduct, and sets forth a procedure for reporting, investigating and resolving complaints of discrimination, harassment, in the workplace, including retaliation and hostile work environment.

II. POLICY
A. The City of Stockton prohibits any form of discrimination and/or harassment of any person based on race, religious creed, color, national origin, ancestry, military and veterans status, physical or mental disability, medical condition, genetic characteristics or information, denial of family and medical care leave, marital status, sexual orientation, sex (including gender, gender identity, gender expression, transgender, pregnancy, childbirth and breastfeeding), political affiliation, age (40 and older), concerted labor activity, or any other category or attribute consistent with state or federal law.

All such discrimination and harassment is unlawful and shall not be tolerated. In addition, under the federal Affordable Care Act (ACA), the City of Stockton prohibits discrimination and/or harassment, or retaliation against an employee who obtains coverage, receives a tax credit or subsidy through the Health Care "Market Place" or "Exchange."
B. It is an unlawful employment practice to discriminate against or to harass an unpaid intern or volunteer on the basis of any legally protected classification unless an exception applies, such as a bona fide occupational qualification.

C. The City will neither tolerate nor condone discrimination and/or harassment of employees by managers, supervisors, co-workers, or non-employees with whom City employees have a business service, or professional relationship.

D. All City employees and non-employees share a responsibility to assist in

EXHIBIT C

EXHIBIT 1
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 2 of 14
DISCRIMINATION AND Effective Date: Revised From: HARASSMENT POLICY 7/27/09 5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 maintaining an employment environment free of discrimination and harassment. This policy applies to all aspects of City employment, including, but not limited to, hiring, reassignment, placement, promotion, employment action, disciplinary action, layoff, reemployment, transfer, leave of absence, compensation and benefits, training; or other terms of treatment of that person in an unpaid internship, or another limited duration program to provide unpaid work experience for that person, or the harassment of an unpaid intern or volunteer.

E. All allegations of discrimination and/or harassment shall be investigated immediately by the City, in accordance with this policy. If it is determined that any prohibited activity has occurred, remedial action shall be taken. Such action may include discipline up to and including discharge. In addition, under applicable law, individual supervisors and employees may be subject to personal liability and/or punitive damages in any litigation arising as a result of such conduct.

F. All new hires shall attend harassment awareness training, and supervisors and managers shall attend harassment awareness and prevention training for supervisors every two years.

G. The City of Stockton prohibits retaliation against any employee or non­ employee by another employee, non-employee, supervisor, or manager for reporting, filing, testifying, assisting or participating in any manner in any investigation, proceeding, or hearing conducted by the employer or a federal or state enforcement agency.

H. This policy applies to all officials, employees, volunteers, unpaid interns, agents, or contractors of the City.

I. This policy shall be administered by the Director of Human Resources.

EXHIBIT C

EXHIBIT 1
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 3 of 14
DISCRIMINATION AND Effective Date: Revised From:

HARASSMENT POLICY 7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment m the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 Ill. DEFINITION AND EXAMPLES OF DISCRIMINATION AND HARASSMENT A. "Discrimination," as used in this policy, is any action, behavior, practice, or process that is intended to deny, or results in the denial of, employment rights, privileges, or benefits because of a person's race, religious creed, color, national origin, ancestry, military and veterans status, physical or mental disability, medical condition, genetic characteristics or information, denial of family and medical care leave, marital status, sexual orientation, sex (including gender, gender identity, gender expression, transgender, pregnancy, childbirth and breastfeeding), political affiliation, age (40 and older), concerted labor activity, or any other prohibition identified under state and federal law. The following are examples of conduct that may constitute discrimination:

1. Soliciting applications from a source where all or most of potential workers are of the same race or color.

2. Considering a person's gender as the basis for differences in pay, work assignments, performance evaluations, training, discipline, or any other area of employment; and

3. Questioning a job applicant about the existence, nature and severity of a disability.

B. "Harassment," as used in this policy, consists of any conduct affecting another person because of his or her race, religious creed, color, national origin, ancestry, military and veterans status, physical or mental disability, medical condition, genetic characteristics or information, denial of family and medical care leave, marital status, sexual orientation, sex (including gender, gender identity, gender expression, transgender, pregnancy, childbirth and breastfeeding), political affiliation, age (40 and older), concerted labor activity, or any other category or attribute identified under state and federal law when such conduct has the purpose or the effect of: (1) creating an intimidating, hostile or offensive work environment; (2) unreasonably interfering with the employee's or non-employee's work performance; or (3)

EXHIBIT C

EXHIBIT 1
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 4 of 14

DISCRIMINATION AND

HARASSMENT POLICY
Effective Date: Revised From:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93 otherwise adversely affecting an employee's or non-employee's employment opportunities.

Harassment may take many forms, including, but not limited to, the following examples:

1. Verbal Harassment: Epithets, derogatory and offensive comments or slurs based on race, religion, color, national origin, ancestry, physical or mental disability, marital status, pregnancy, medical condition, gender, sexual orientation, political affiliation, age, or any other category or attribute identified under state and federal law.

2. Physical Harassment: Assault, impeding or blocking movement that results in the physical interference with normal work or movement on the basis of race, religion, color, national origin, ancestry, physical or mental disability, marital status, pregnancy, medical condition, gender, sexual orientation, political affiliation, age, or any other category or attribute identified under state and federal law.

3. Visual Harassment: The displaying of posters, photography, notices, bulletins, e-mails, cartoons or drawings with derogatory and offensive content based on race, religion, color, national origin, ancestry, physical or mental disability, marital status, pregnancy, medical condition, gender, sexual orientation, political affiliation, age, or any other category or attribute identified under state and federal law.

C. "Sexual harassment," as used in this policy, is a subcategory of harassment, and is specifically defined by law as unwanted sexual advances, requests for sexual favors or visual, verbal or physical conduct of a sexual nature when:

1. Submission to such conduct is made a term or condition of employment; or

2. Submission to or rejection of such conduct is used as a basis for employment decisions affecting the individual; or

EXHIBIT C

EXHIBIT 1
Subject:

CITY OF STOCKTON, CALIFORNIA

CITY MANAGER ADMINISTRATIVE DIRECTIVE
Directive No. HR-15 Page No. 5 of 14

DISCRIMINATION AND

HARASSMENT POLICY
Effective Date: Revised From:
7/27/09
5/1/2015 4/6/09
3/1/2010
(see below)
PER-015 (Sexual Harassment in the Workplace) revised from 10/21/94, 5/1/95, 1/1/98 PER-037 (Sexual Harassment Investigative Procedures) revised from 2/15/93

3. Such conduct has the purpose or effect of unreasonably interfering with an employee's or non-employee's work performance or creating an intimidating, hostile or offensive working environment because of the persistent, severe or pervasive nature of the conduct.

Examples of Sexual Harassment include, but are not limited to the following:
a. Unwelcome sexual overtures or propositions.
b. Offering employment benefits or status in exchange for sexual favors.
c. Making or threatening retaliation after a negative response to sexual advances.
d. Visual conduct such as leering, making sexual gestures, displaying sexually suggestive objects or pictures, cartoons, calendars or posters.
e. Verbal conduct such as using epithets or slurs, telling sexually explicit jokes, or making derogatory or suggestive comments about a person's body or dress.
f. Written communications of a sexual nature distributed in hard copy, soft copy or via a computer network.
g. Verbal abuse of a sexual nature, graphic verbal commentary about an individual's body, sexually degrading words to describe an individual, suggestive or obscene letters, notes or invitations.
h. Physical conduct such as touching, assaulting, impeding or blocking movements.

EXHIBIT C

EXHIBIT 1

EXHIBIT C

EXHIBIT 1

EXHIBIT C

EXHIBIT 1

EXHIBIT C

EXHIBIT 1

EXHIBIT C

EXHIBIT 1

EXHIBIT C

EXHIBIT 1

EXHIBIT C

EXHIBIT 1

EXHIBIT C

EXHIBIT 1

EXHIBIT C

EXHIBIT 1

EXHIBIT C

EXHIBIT 1
"General Decision Number: CA20250018 08/15/2025
Superseded General Decision Number: CA20240018
State: California
Construction Types: Building, Heavy (Heavy and Dredging) and Highway
Counties: Alameda, Calaveras, Contra Costa, Fresno, Kings, Madera, Mariposa, Merced, Monterey, San Benito, San Francisco, San Joaquin, San Mateo, Santa Clara, Santa Cruz, Stanislaus and Tuolumne Counties in California.

BUILDING CONSTRUCTION PROJECTS; DREDGING PROJECTS (does not include hopper dredge work); HEAVY CONSTRUCTION PROJECTS (does not include water well drilling); HIGHWAY CONSTRUCTION PROJECTS Note: Contracts subject to the Davis-Bacon Act are generally required to pay at least the applicable minimum wage rate required under Executive Order 14026 or Executive Order 13658.

Please note that these Executive Orders apply to covered contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but do not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(1).
______________________________________________________________ |If the contract is entered |. Executive Order 14026 | |into on or after January 30, | generally applies to the | |2022, or the contract is | contract. |
|renewed or extended (e.g., an |. The contractor must pay | |option is exercised) on or | all covered workers at | |after January 30, 2022: | least $17.75 per hour (or | | | the applicable wage rate |
| | listed on this wage |
| | determination, if it is |
| | higher) for all hours |
| | spent performing on the |
| | contract in 2025. |
|______________________________|_____________________________| |If the contract was awarded on|. Executive Order 13658 | |or between January 1, 2015 and| generally applies to the | |January 29, 2022, and the | contract. |
|contract is not renewed or |. The contractor must pay all| |extended on or after January | covered workers at least | |30, 2022: | $13.30 per hour (or the |
| | applicable wage rate listed|
| | on this wage determination,|
| | if it is higher) for all |
| | hours spent performing on |
| | that contract in 2025. |
|______________________________|_____________________________| The applicable Executive Order minimum wage rate will be adjusted annually. If this contract is covered by one of the Executive Orders and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must still submit a
conformance request.

Additional information on contractor requirements and worker

EXHIBIT D

EXHIBIT 1
protections under the Executive Orders is available at
http://www.dol.gov/whd/govcontracts.

Modification Number Publication Date
0 01/03/2025
1 01/10/2025
2 02/07/2025
3 02/21/2025
4 02/28/2025
5 03/07/2025
6 03/21/2025
7 05/23/2025
8 06/06/2025
9 06/27/2025
10 07/04/2025
11 07/11/2025
12 07/18/2025
13 08/01/2025
14 08/08/2025
15 08/15/2025
ASBE0016-004 05/01/2024
AREA 1: CALAVERAS, FRESNO, KINGS, MADERA, MARIPOSA, MERCED,

MONTEREY, SAN BENITO, SAN JOAQUIN, SANTA CRUZ, STANISLAUS &

TOULMNE COUNTIES
AREA 2: ALAMEDA, CONTRA COSTA, SAN FRANCISCO, SAN MATEO & SANTA

CLARA COUNTIES
Rates Fringes
Asbestos Removal
worker/hazardous material
handler (Includes
preparation, wetting,
stripping, removal,
scrapping, vacuuming, bagging
and disposing of all
insulation materials from
mechanical systems, whether
they contain asbestos or not)
Area 1......................$ 34.56 11.40
Area 2......................$ 36.53 9.27
---------------------------------------------------------------- ASBE0016-008 01/01/2024
AREA 1: ALAMEDA, CONTRA COSTA, MONTEREY, SAN BENITO, SAN

FRANCISCO, SAN MATEO, SANTA CLARA, & SANTA CRUZ
AREA 2: CALAVERAS, COLUSA, FRESNO, KINGS, MADERA, MARIPOSA,

MERCED, SAN JOAQUIN, STANISLAUS, & TUOLUMNE
Rates Fringes
Asbestos Workers/Insulator
(Includes the application of
all insulating materials,
Protective Coverings,
Coatings, and Finishes to all
types of mechanical systems)
Area 1......................$ 84.76 25.07

EXHIBIT D

EXHIBIT 1
Area 2......................$ 64.56 25.07
---------------------------------------------------------------- BOIL0549-001 01/01/2021
AREA 1: ALAMEDA, CONTRA COSTA, SAN FRANCISCO, SAN MATEO & SANTA

CLARA COUNTIES
AREA 2: REMAINING COUNTIES
Rates Fringes

BOILERMAKER
Area 1......................$ 49.62 41.27
Area 2......................$ 45.60 38.99
---------------------------------------------------------------- BRCA0003-001 08/01/2024
Rates Fringes
MARBLE FINISHER..................$ 42.06 19.80 ---------------------------------------------------------------- BRCA0003-003 08/01/2024
Rates Fringes
MARBLE MASON.....................$ 61.72 30.31 ---------------------------------------------------------------- BRCA0003-005 05/01/2024
Rates Fringes

BRICKLAYER
( 1) Fresno, Kings,
Madera, Mariposa, Merced....$ 51.17 25.80
( 7) San Francisco, San
Mateo.......................$ 57.02 28.50
( 8) Alameda, Contra
Costa, San Benito, Santa
Clara.......................$ 56.94 26.28
( 9) Calaveras, San
Joaquin, Stanislaus,
Toulumne....................$ 52.76 25.01
(16) Monterey, Santa Cruz...$ 54.18 27.82
---------------------------------------------------------------- BRCA0003-008 07/01/2024
Rates Fringes
TERRAZZO FINISHER................$ 44.93 20.98 TERRAZZO WORKER/SETTER...........$ 60.58 29.79 ---------------------------------------------------------------- BRCA0003-011 04/01/2024
AREA 1: Alameda, Contra Costa, Monterey, San Benito, San Francisco, San Mateo, Santa Clara, Santa Cruz
AREA 2: Calaveras, San Joaquin, Stanislaus, Tuolumne
AREA 3: Fresno, Kings, Madera, Mariposa, Merced
Rates Fringes

TILE FINISHER

EXHIBIT D

EXHIBIT 1
Area 1......................$ 37.75 19.28
Area 2......................$ 34.76 19.22
Area 3......................$ 32.68 18.32
Tile Layer
Area 1......................$ 59.92 22.62
Area 2......................$ 55.17 22.52
Area 3......................$ 50.28 22.05
---------------------------------------------------------------- CARP0022-001 07/01/2023
San Francisco County
Rates Fringes
Carpenters
Bridge Builder/Highway
Carpenter...................$ 60.39 33.52
Hardwood Floorlayer,
Shingler, Power Saw
Operator, Steel Scaffold &
Steel Shoring Erector, Saw
Filer.......................$ 60.54 33.52
Journeyman Carpenter........$ 60.39 33.52
Millwright..................$ 60.49 35.11
---------------------------------------------------------------- CARP0034-001 07/01/2021
Rates Fringes
Diver
Assistant Tender, ROV
Tender/Technician...........$ 54.10 34.69
Diver standby...............$ 60.51 34.69
Diver Tender................$ 59.51 34.69
Diver wet...................$ 103.62 34.69
Manifold Operator (mixed
gas)........................$ 64.51 34.69
Manifold Operator (Standby).$ 59.51 34.69
DEPTH PAY (Surface Diving):
050 to 100 ft $2.00 per foot
101 to 150 ft $3.00 per foot
151 to 220 ft $4.00 per foot
221 ft.-deeper $5.00 per foot
SATURATION DIVING:

The standby rate shall apply until saturation starts. The saturation diving rate applies when divers are under
pressure continuously until work task and decompression are complete. The diver rate shall be paid for all saturation hours.

DIVING IN ENCLOSURES:

Where it is necessary for Divers to enter pipes or tunnels, or other enclosures where there is no vertical ascent, the following premium shall be paid: Distance traveled from entrance 26 feet to 300 feet: $1.00 per foot. When it is necessary for a diver to enter any pipe, tunnel or other enclosure less than 48"" in height, the premium will be $1.00 per foot.

WORK IN COMBINATION OF CLASSIFICATIONS:

Employees working in any combination of classifications within the diving crew (except dive supervisor) in a shift are paid in the classification with the highest rate for

EXHIBIT D

EXHIBIT 1
that shift.
---------------------------------------------------------------- CARP0034-003 07/01/2021
Rates Fringes
Piledriver.......................$ 54.10 34.69 ---------------------------------------------------------------- CARP0035-007 07/01/2020
AREA 1: Alameda, Contra Costa, San Francisco, San Mateo, Santa Clara counties
AREA 2: Monterey, San Benito, Santa Cruz Counties
AREA 3: Calaveras, Fresno, Kings, Madera, Mariposa, Merced, San Joaquin, Stanislaus, Tuolumne Counties
Rates Fringes
Modular Furniture Installer
Area 1
Installer..................$ 28.76 22.53
Lead Installer.............$ 32.21 23.03
Master Installer...........$ 36.43 23.03
Area 2
Installer..................$ 26.11 22.53
Lead Installer.............$ 29.08 23.03
Master Installer...........$ 32.71 23.03
Area 3
Installer..................$ 25.16 22.53
Lead Installer.............$ 27.96 23.03
Master Installer...........$ 31.38 23.03
---------------------------------------------------------------- CARP0035-008 08/01/2020
AREA 1: Alameda, Contra Costa, San Francisco, San Mateo, Santa Clara counties
AREA 2: Monterey, San Benito, Santa Cruz Counties
AREA 3: San Joaquin
AREA 4: Calaveras, Fresno, Kings, Madera, Mariposa, Merced, Stanislaus, Tuolumne Counties
Rates Fringes
Drywall Installers/Lathers:

Area 1......................$ 52.65 31.26
Area 2......................$ 46.77 31.26
Area 3......................$ 47.27 31.26
Area 4......................$ 45.92 31.26
Drywall Stocker/Scrapper
Area 1......................$ 26.33 18.22
Area 2......................$ 23.39 18.22
Area 3......................$ 23.64 18.22
Area 4......................$ 22.97 18.22
---------------------------------------------------------------- CARP0152-001 07/01/2020
Contra Costa County

EXHIBIT D

EXHIBIT 1
Rates Fringes
Carpenters
Bridge Builder/Highway
Carpenter...................$ 52.65 30.82
Hardwood Floorlayer,
Shingler, Power Saw
Operator, Steel Scaffold &
Steel Shoring Erector, Saw
Filer.......................$ 52.80 30.82
Journeyman Carpenter........$ 52.65 30.82
Millwright..................$ 52.75 32.41
---------------------------------------------------------------- CARP0152-002 07/01/2020
San Joaquin County
Rates Fringes
Carpenters
Bridge Builder/Highway
Carpenter...................$ 52.65 30.82
Hardwood Floorlayer,
Shingler, Power Saw
Operator, Steel Scaffold &
Steel Shoring Erector, Saw
Filer.......................$ 46.92 30.82
Journeyman Carpenter........$ 46.77 30.82
Millwright..................$ 49.27 32.41
---------------------------------------------------------------- CARP0152-004 07/01/2020
Calaveras, Mariposa, Merced, Stanislaus and Tuolumne Counties Rates Fringes
Carpenters
Bridge Builder/Highway
Carpenter...................$ 52.65 30.82
Hardwood Floorlayer,
Shingler, Power Saw
Operator, Steel Scaffold &
Steel Shoring Erector, Saw
Filer.......................$ 45.57 30.82
Journeyman Carpenter........$ 45.42 30.82
Millwright..................$ 47.92 32.41
---------------------------------------------------------------- CARP0217-001 07/01/2023
San Mateo County
Rates Fringes
Carpenters
Bridge Builder/Highway
Carpenter...................$ 60.39 33.52
Hardwood Floorlayer,
Shingler, Power Saw
Operator, Steel Scaffold &
Steel Shoring Erector, Saw
Filer.......................$ 60.54 33.52
Journeyman Carpenter........$ 60.39 33.52
Millwright..................$ 60.49 35.11
----------------------------------------------------------------

EXHIBIT D

EXHIBIT 1
CARP0405-001 07/01/2021
Santa Clara County
Rates Fringes
Carpenters
Bridge Builder/Highway
Carpenter...................$ 54.85 31.49
Hardwood Floorlayer,
Shingler, Power Saw
Operator, Steel Scaffold &
Steel Shoring Erector, Saw
Filer.......................$ 55.00 31.49
Journeyman Carpenter........$ 54.85 31.49
Millwright..................$ 54.95 33.08
---------------------------------------------------------------- CARP0405-002 07/01/2021
San Benito County
Rates Fringes
Carpenters
Bridge Builder/Highway
Carpenter...................$ 54.85 31.49
Hardwood Floorlayer,
Shingler, Power Saw
Operator, Steel Scaffold &
Steel Shoring Erector, Saw
Filer.......................$ 49.12 31.49
Journeyman Carpenter........$ 48.97 31.49
Millwright..................$ 51.47 33.08
---------------------------------------------------------------- CARP0505-001 07/01/2021
Santa Cruz County
Rates Fringes
Carpenters
Bridge Builder/Highway
Carpenter...................$ 54.85 31.49
Hardwood Floorlayer,
Shingler, Power Saw
Operator, Steel Scaffold &
Steel Shoring Erector, Saw
Filer.......................$ 49.12 31.49
Journeyman Carpenter........$ 48.97 31.49
Millwright..................$ 51.47 33.08
---------------------------------------------------------------- CARP0605-001 07/01/2021
Monterey County
Rates Fringes
Carpenters
Bridge Builder/Highway
Carpenter...................$ 54.85 31.49
Hardwood Floorlayer,
Shingler, Power Saw
Operator, Steel Scaffold &
Steel Shoring Erector, Saw
Filer.......................$ 49.12 31.49

EXHIBIT D

EXHIBIT 1
Journeyman Carpenter........$ 48.97 31.49
Millwright..................$ 51.47 33.08
---------------------------------------------------------------- CARP0701-001 07/01/2021
Fresno and Madera Counties
Rates Fringes
Carpenters
Bridge Builder/Highway
Carpenter...................$ 54.85 31.49
Hardwood Floorlayer,
Shingler, Power Saw
Operator, Steel Scaffold &
Steel Shoring Erector, Saw
Filer.......................$ 47.77 31.49
Journeyman Carpenter........$ 47.62 31.49
Millwright..................$ 50.12 33.08
---------------------------------------------------------------- CARP0713-001 07/01/2021
Alameda County
Rates Fringes
Carpenters
Bridge Builder/Highway
Carpenter...................$ 54.85 31.49
Hardwood Floorlayer,
Shingler, Power Saw
Operator, Steel Scaffold &
Steel Shoring Erector, Saw
Filer.......................$ 55.00 31.49
Journeyman Carpenter........$ 54.85 31.49
Millwright..................$ 54.95 33.08
---------------------------------------------------------------- CARP1109-001 07/01/2021
Kings County
Rates Fringes
Carpenters
Bridge Builder/Highway
Carpenter...................$ 54.85 31.49
Hardwood Floorlayer,
Shingler, Power Saw
Operator, Steel Scaffold &
Steel Shoring Erector, Saw
Filer.......................$ 47.77 31.49
Journeyman Carpenter........$ 47.62 31.49
Millwright..................$ 50.12 33.08
---------------------------------------------------------------- ELEC0006-004 12/01/2024

SAN FRANCISCO COUNTY
Rates Fringes
Sound & Communications
Installer...................$ 57.18 3%+27.15
Technician..................$ 65.76 3%+27.15
SCOPE OF WORK: Including any data system whose only function

EXHIBIT D

EXHIBIT 1
is to transmit or receive information; excluding all other data systems or multiple systems which include control function or power supply; inclusion or exclusion of
terminations and testings of conductors determined by
their function; excluding fire alarm work when installed in raceways (including wire and cable pulling) and when performed on new or major remodel building projects or jobs for which the conductors for the fire alarm system are installed in conduit; excluding installation of raceway systems, line voltage work, industrial work, life-safety systems (all buildings having floors located more than 75' above the lowest floor level having building access);
excluding energy management systems.

FOOTNOTE: Fire alarm work when installed in raceways
(including wire and cable pulling), on projects which
involve new or major remodel building construction, for which the conductors for the fire alarm system are
installed in the conduit, shall be performed by the inside electrician.
---------------------------------------------------------------- ELEC0006-007 06/01/2024

SAN FRANCISCO COUNTY
Rates Fringes
ELECTRICIAN......................$ 91.25 3%+45.315 ---------------------------------------------------------------- ELEC0100-002 03/01/2025

FRESNO, KINGS, AND MADERA COUNTIES
Rates Fringes
ELECTRICIAN......................$ 49.00 29.62 ---------------------------------------------------------------- ELEC0100-005 12/01/2024

FRESNO, KINGS, MADERA
Rates Fringes
Communications System
Installer...................$ 45.28 28.01
Technician..................$ 52.07 28.21

SCOPE OF WORK
Includes the installation testing, service and maintenance, of the following systems which utilize the transmission and/or transference of voice, sound, vision and digital for commercial, education, security and entertainment purposes for the following: TV monitoring and surveillance,
background-foreground music, intercom and telephone
interconnect, inventory control systems, microwave
transmission, multi-media, multiplex, nurse call system, radio page, school intercom and sound, burglar alarms, and low voltage master clock systems.

A. SOUND AND VOICE TRANSMISSION/TRANSFERENCE SYSTEMS
Background foreground music, Intercom and telephone
interconnect systems, Telephone systems Nurse call systems, Radio page systems, School intercom and sound systems,
Burglar alarm systems, Low voltage, master clock systems,

EXHIBIT D

EXHIBIT 1
Multi-media/multiplex systems, Sound and musical
entertainment systems, RF systems, Antennas and Wave Guide, B. FIRE ALARM SYSTEMS Installation, wire pulling and testing C. TELEVISION AND VIDEO SYSTEMS Television monitoring and surveillance systems Video security systems, Video
entertainment systems, Video educational systems, Microwave transmission systems, CATV and CCTV
D. SECURITY SYSTEMS Perimeter security systems Vibration sensor systems Card access systems Access control systems, Sonar/infrared monitoring equipment
E. COMMUNICATIONS SYSTEMS THAT TRANSMIT OR RECEIVE

INFORMATION AND/OR CONTROL SYSTEMS THAT ARE INTRINSIC TO THE ABOVE LISTED SYSTEMS SCADA (Supervisory Control and Data Acquisition) PCM (Pulse Code Modulation) Inventory Control Systems, Digital Data Systems Broadband and
Baseband and Carriers Point of Sale Systems, VSAT Data
Systems Data Communication Systems RF and Remote Control Systems, Fiber Optic Data Systems
WORK EXCLUDED Raceway systems are not covered (excluding Ladder-Rack for the purpose of the above listed systems).

Chases and/or nipples (not to exceed 10 feet) may be
installed on open wiring systems. Energy management
systems. SCADA (Supervisory Control and Data Acquisition) when not intrinsic to the above listed systems (in the
scope). Fire alarm systems when installed in raceways
(including wire and cable pulling) shall be performed at the electrician wage rate, when either of the following two (2) conditions apply:

1. The project involves new or major remodel building trades construction.

2. The conductors for the fire alarm system are installed in conduit.
---------------------------------------------------------------- ELEC0234-001 12/23/2024

MONTEREY, SAN BENITO AND SANTA CRUZ COUNTIES
Rates Fringes

ELECTRICIAN
Zone A......................$ 68.16 31.29
Zone B......................$ 74.98 31.50
Zone A: All of Santa Cruz, Monterey, and San Benito Counties within 25 air miles of Highway 1 and Dolan Road in Moss Landing, and an area extending 5 miles east and west of Highway 101 South to the San Luis Obispo County Line
Zone B: Any area outside of Zone A
---------------------------------------------------------------- ELEC0234-003 12/01/2021

MONTEREY, SAN BENITO, AND SANTA CRUZ COUNTIES
Rates Fringes
Sound & Communications
Installer...................$ 47.93 24.09

EXHIBIT D

EXHIBIT 1
Technician..................$ 55.12 24.30
SCOPE OF WORK: Including any data system whose only function is to transmit or receive information; excluding all other data systems or multiple systems which include control function or power supply; inclusion or exclusion of
terminations and testings of conductors determined by
their function; excluding fire alarm work when installed in raceways (including wire and cable pulling) and when performed on new or major remodel building projects or jobs for which the conductors for the fire alarm system are installed in conduit; excluding installation of raceway systems, line voltage work, industrial work, life-safety systems (all buildings having floors located more than 75' above the lowest floor level having building access);
excluding energy management systems.

FOOTNOTE: Fire alarm work when installed in raceways
(including wire and cable pulling), on projects which
involve new or major remodel building construction, for which the conductors for the fire alarm system are
installed in the conduit, shall be performed by the inside electrician.
---------------------------------------------------------------- ELEC0302-001 03/01/2025

CONTRA COSTA COUNTY
Rates Fringes
CABLE SPLICER....................$ 74.54 36.09 ELECTRICIAN......................$ 66.26 35.84 ---------------------------------------------------------------- ELEC0302-003 12/01/2023

CONTRA COSTA COUNTY
Rates Fringes
Sound & Communications
Installer...................$ 48.44 27.60
Technician..................$ 55.71 27.82
SCOPE OF WORK: Including any data system whose only function is to transmit or receive information; excluding all other data systems or multiple systems which include control function or power supply; inclusion or exclusion of
terminations and testings of conductors determined by
their function; excluding fire alarm work when installed in raceways (including wire and cable pulling) and when performed on new or major remodel building projects or jobs for which the conductors for the fire alarm system are installed in conduit; excluding installation of raceway systems, line voltage work, industrial work, life-safety systems (all buildings having floors located more than 75' above the lowest floor level having building access);
excluding energy management systems.

FOOTNOTE: Fire alarm work when installed in raceways
(including wire and cable pulling), on projects which
involve new or major remodel building construction, for which the conductors for the fire alarm system are
installed in the conduit, shall be performed by the inside electrician.

EXHIBIT D

EXHIBIT 1
---------------------------------------------------------------- ELEC0332-001 06/01/2025

SANTA CLARA COUNTY
Rates Fringes
CABLE SPLICER....................$ 104.68 49.46 ELECTRICIAN......................$ 91.03 49.05 FOOTNOTES: Work under compressed air or where gas masks are required, orwork on ladders, scaffolds, stacks, ""Bosun's chairs,"" or other structures and where the workers are not protected by permanent guard rails at a distance of 40 to 60 ft. from the ground or supporting structures: to be paid one and one-half times the straight-time rate of pay.

Work on structures of 60 ft. or over (as described above):
to be paid twice the straight-time rate of pay.
---------------------------------------------------------------- ELEC0332-003 12/01/2024

SANTA CLARA COUNTY
Rates Fringes
Sound & Communications
Installer...................$ 56.68 28.35
Technician..................$ 65.18 28.61
SCOPE OF WORK: Including any data system whose only function is to transmit or receive information; excluding all other data systems or multiple systems which include control function or power supply; inclusion or exclusion of
terminations and testings of conductors determined by
their function; excluding fire alarm work when installed in raceways (including wire and cable pulling) and when performed on new or major remodel building projects or jobs for which the conductors for the fire alarm system are installed in conduit; excluding installation of raceway systems, line voltage work, industrial work, life-safety systems (all buildings having floors located more than 75' above the lowest floor level having building access);
excluding energy management systems.

FOOTNOTE: Fire alarm work when installed in raceways
(including wire and cable pulling), on projects which
involve new or major remodel building construction, for which the conductors for the fire alarm system are
installed in the conduit, shall be performed by the inside electrician.
---------------------------------------------------------------- ELEC0595-001 06/01/2025

ALAMEDA COUNTY
Rates Fringes
CABLE SPLICER....................$ 87.40 3%+46.79 ELECTRICIAN......................$ 76.00 3%+46.79 ---------------------------------------------------------------- ELEC0595-002 06/01/2024

EXHIBIT D

EXHIBIT 1

CALAVERAS AND SAN JOAQUIN COUNTIES
Rates Fringes
CABLE SPLICER....................$ 59.34 3%+30.48

ELECTRICIAN
(1) Tunnel work.............$ 51.92 3%+30.48
(2) All other work.........$ 49.45 3%+30.48
---------------------------------------------------------------- ELEC0595-006 12/01/2024

ALAMEDA COUNTY
Rates Fringes
Sound & Communications
Installer...................$ 56.68 3%+26.65
Technician..................$ 65.18 3%+26.65
SCOPE OF WORK: Including any data system whose only function is to transmit or receive information; excluding all other data systems or multiple systems which include control function or power supply; inclusion or exclusion of
terminations and testings of conductors determined by
their function; excluding fire alarm work when installed in raceways (including wire and cable pulling) and when performed on new or major remodel building projects or jobs for which the conductors for the fire alarm system are installed in conduit; excluding installation of raceway systems, line voltage work, industrial work, life-safety systems (all buildings having floors located more than 75' above the lowest floor level having building access);
excluding energy management systems.

FOOTNOTE: Fire alarm work when installed in raceways
(including wire and cable pulling), on projects which
involve new or major remodel building construction, for which the conductors for the fire alarm system are
installed in the conduit, shall be performed by the inside electrician.
---------------------------------------------------------------- ELEC0595-008 12/01/2024

CALAVERAS AND SAN JOAQUIN COUNTIES
Rates Fringes
Communications System
Installer...................$ 45.28 3%+26.65
Technician..................$ 52.07 3%+26.65
SCOPE OF WORK: Including any data system whose only function is to transmit or receive information; excluding all other data systems or multiple systems which include control function or power supply; inclusion or exclusion of
terminations and testings of conductors determined by
their function; excluding fire alarm work when installed in raceways (including wire and cable pulling) and when performed on new or major remodel building projects or jobs for which the conductors for the fire alarm system are installed in conduit; excluding installation of raceway systems, line voltage work, industrial work, life-safety systems (all buildings having floors located more than 75' above the lowest floor level having building access);

EXHIBIT D

EXHIBIT 1
excluding energy management systems.

FOOTNOTE: Fire alarm work when installed in raceways
(including wire and cable pulling), on projects which
involve new or major remodel building construction, for which the conductors for the fire alarm system are
installed in the conduit, shall be performed by the inside electrician.
---------------------------------------------------------------- ELEC0617-001 06/01/2025

SAN MATEO COUNTY
Rates Fringes
ELECTRICIAN......................$ 86.00 51.07 ---------------------------------------------------------------- ELEC0617-003 12/01/2023

SAN MATEO COUNTY
Rates Fringes
Sound & Communications
Installer...................$ 53.18 27.75
Technician..................$ 61.16 27.98
SCOPE OF WORK: Including any data system whose only function is to transmit or receive information; excluding all other data systems or multiple systems which include control function or power supply; inclusion or exclusion of
terminations and testings of conductors determined by
their function; excluding fire alarm work when installed in raceways (including wire and cable pulling) and when performed on new or major remodel building projects or jobs for which the conductors for the fire alarm system are installed in conduit; excluding installation of raceway systems, line voltage work, industrial work, life-safety systems (all buildings having floors located more than 75' above the lowest floor level having building access);
excluding energy management systems.

FOOTNOTE: Fire alarm work when installed in raceways
(including wire and cable pulling), on projects which
involve new or major remodel building construction, for which the conductors for the fire alarm system are
installed in the conduit, shall be performed by the inside electrician.
---------------------------------------------------------------- ELEC0684-001 12/01/2024

MARIPOSA, MERCED, STANISLAUS AND TUOLUMNE COUNTIES
Rates Fringes
ELECTRICIAN......................$ 48.50 30.09 CABLE SPLICER = 110% of Journeyman Electrician
---------------------------------------------------------------- ELEC0684-004 12/01/2024

MARIPOSA, MERCED, STANISLAUS AND TUOLUMNE COUNTIES

EXHIBIT D

EXHIBIT 1
Rates Fringes
Communications System
Installer...................$ 45.28 28.01
Technician..................$ 52.07 28.21
SCOPE OF WORK: Including any data system whose only function is to transmit or receive information; excluding all other data systems or multiple systems which include control function or power supply; inclusion or exclusion of
terminations and testings of conductors determined by
their function; excluding fire alarm work when installed in raceways (including wire and cable pulling) and when performed on new or major remodel building projects or jobs for which the conductors for the fire alarm system are installed in conduit; excluding installation of raceway systems, line voltage work, industrial work, life-safety systems (all buildings having floors located more than 75' above the lowest floor level having building access);
excluding energy management systems.

FOOTNOTE: Fire alarm work when installed in raceways
(including wire and cable pulling), on projects which
involve new or major remodel building construction, for which the conductors for the fire alarm system are
installed in the conduit, shall be performed by the inside electrician.
---------------------------------------------------------------- ELEC1245-001 01/01/2025
Rates Fringes

LINE CONSTRUCTION
(1) Lineman; Cable splicer..$ 70.16 24.71
(2) Equipment specialist
(operates crawler
tractors, commercial motor
vehicles, backhoes,
trenchers, cranes (50 tons
and below), overhead &
underground distribution
line equipment).............$ 53.30 22.26
(3) Groundman...............$ 40.76 21.76
(4) Powderman...............$ 51.87 18.79
HOLIDAYS: New Year's Day, M.L. King Day, Memorial Day,
Independence Day, Labor Day, Veterans Day, Thanksgiving Day and day after Thanksgiving, Christmas Day
---------------------------------------------------------------- ELEV0008-001 01/01/2025
Rates Fringes
ELEVATOR MECHANIC................$ 84.05 38.435+a+b FOOTNOTE:
a. PAID VACATION: Employer contributes 8% of regular hourly rate as vacation pay credit for employees with more than 5 years of service, and 6% for 6 months to 5 years of service. b. PAID HOLIDAYS: New Year's Day, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day, Friday after Thanksgiving, and Christmas Day.

EXHIBIT D

EXHIBIT 1
---------------------------------------------------------------- ENGI0003-001 07/01/2024
""AREA 1"" WAGE RATES ARE LISTED BELOW
""AREA 2"" RECEIVES AN ADDITIONAL $2.00 PER HOUR ABOVE AREA 1 RATES.

SEE AREA DEFINITIONS BELOW
Rates Fringes
OPERATOR: Power Equipment
(AREA 1:)
GROUP 1.....................$ 64.15 30.89
GROUP 2.....................$ 62.62 30.89
GROUP 3.....................$ 61.14 30.89
GROUP 4.....................$ 59.76 30.89
GROUP 5.....................$ 58.49 30.89
GROUP 6.....................$ 57.17 30.89
GROUP 7.....................$ 56.03 30.89
GROUP 8.....................$ 54.89 30.89
GROUP 8-A...................$ 52.68 30.89
OPERATOR: Power Equipment
(Cranes and Attachments -
AREA 1:)
GROUP 1
Cranes.....................$ 52.30 31.15
Oiler......................$ 43.79 31.15
Truck crane oiler..........$ 46.08 31.15
GROUP 2
Cranes.....................$ 50.54 31.15
Oiler......................$ 42.83 31.15
Truck crane oiler..........$ 45.07 31.15
GROUP 3
Cranes.....................$ 48.80 31.15
Hydraulic..................$ 44.44 31.15
Oiler......................$ 42.55 31.15
Truck crane oiler..........$ 44.83 31.15
GROUP 4
Cranes.....................$ 45.76 31.15
OPERATOR: Power Equipment
(Piledriving - AREA 1:)
GROUP 1
Lifting devices............$ 52.64 31.15
Oiler......................$ 43.38 31.15
Truck Crane Oiler..........$ 45.66 31.15
GROUP 2
Lifting devices............$ 50.82 31.15
Oiler......................$ 43.11 31.15
Truck Crane Oiler..........$ 45.41 31.15
GROUP 3
Lifting devices............$ 49.14 31.15
Oiler......................$ 42.89 31.15
Truck Crane Oiler..........$ 45.12 31.15
GROUP 4
Lifting devices............$ 47.37 31.15
GROUP 5
Lifting devices............$ 44.73 31.15
GROUP 6
Lifting devices............$ 42.50 31.15
OPERATOR: Power Equipment
(Steel Erection - AREA 1:)
GROUP 1

EXHIBIT D

EXHIBIT 1
Cranes.....................$ 53.27 31.15
Oiler......................$ 43.72 31.15
Truck Crane Oiler..........$ 45.95 31.15
GROUP 2
Cranes.....................$ 51.50 31.15
Oiler......................$ 43.45 31.15
Truck Crane Oiler..........$ 45.73 31.15
GROUP 3
Cranes.....................$ 50.02 31.15
Hydraulic..................$ 45.07 31.15
Oiler......................$ 43.23 31.15
Truck Crane Oiler..........$ 45.46 31.15
GROUP 4
Cranes.....................$ 48.00 31.15
GROUP 5
Cranes.....................$ 46.70 31.15
OPERATOR: Power Equipment
(Tunnel and Underground Work
- AREA 1:)
SHAFTS, STOPES, RAISES:

GROUP 1....................$ 60.25 30.89
GROUP 1-A..................$ 62.72 30.89
GROUP 2....................$ 58.99 30.89
GROUP 3....................$ 57.66 30.89
GROUP 4....................$ 56.52 30.89
GROUP 5....................$ 55.38 30.89
UNDERGROUND:

GROUP 1....................$ 60.15 30.89
GROUP 1-A..................$ 62.62 30.89
GROUP 2....................$ 58.89 30.89
GROUP 3....................$ 57.56 30.89
GROUP 4....................$ 56.42 30.89
GROUP 5....................$ 55.28 30.89
FOOTNOTE: Work suspended by ropes or cables, or work on a Yo-Yo Cat: $.60 per hour additional.

POWER EQUIPMENT OPERATOR CLASSIFICATIONS
GROUP 1: Operator of helicopter (when used in erection work); Hydraulic excavator, 7 cu. yds. and over; Power shovels, over 7 cu. yds.

GROUP 2: Highline cableway; Hydraulic excavator, 3-1/2 cu. yds. up to 7 cu. yds.; Licensed construction work boat
operator, on site; Power blade operator (finish); Power shovels, over 1 cu. yd. up to and including 7 cu. yds.
m.r.c.

GROUP 3: Asphalt milling machine; Cable backhoe; Combination backhoe and loader over 3/4 cu. yds.; Continuous flight tie back machine assistant to engineer or mechanic; Crane
mounted continuous flight tie back machine, tonnage to
apply; Crane mounted drill attachment, tonnage to apply; Dozer, slope brd; Gradall; Hydraulic excavator, up to 3 1/2 cu. yds.; Loader 4 cu. yds. and over; Long reach excavator; Multiple engine scraper (when used as push pull); Power shovels, up to and including 1 cu. yd.; Pre-stress wire wrapping machine; Side boom cat, 572 or larger; Track
loader 4 cu. yds. and over; Wheel excavator (up to and
including 750 cu. yds. per hour)
GROUP 4: Asphalt plant engineer/box person; Chicago boom; Combination backhoe and loader up to and including 3/4 cu.

EXHIBIT D

EXHIBIT 1
yd.; Concrete batch plant (wet or dry); Dozer and/or push cat; Pull- type elevating loader; Gradesetter, grade
checker (GPS, mechanical or otherwise); Grooving and
grinding machine; Heading shield operator; Heavy-duty
drilling equipment, Hughes, LDH, Watson 3000 or similar; Heavy-duty repairperson and/or welder; Lime spreader;
Loader under 4 cu. yds.; Lubrication and service engineer (mobile and grease rack); Mechanical finishers or spreader machine (asphalt, Barber-Greene and similar); Miller
Formless M-9000 slope paver or similar; Portable crushing and screening plants; Power blade support; Roller operator, asphalt; Rubber-tired scraper, self-loading (paddle-wheels, etc.); Rubber- tired earthmoving equipment (scrapers); Slip form paver (concrete); Small tractor with drag; Soil
stabilizer (P & H or equal); Spider plow and spider puller; Tubex pile rig; Unlicensed constuction work boat operator, on site; Timber skidder; Track loader up to 4 yds.;
Tractor-drawn scraper; Tractor, compressor drill
combination; Welder; Woods-Mixer (and other similar Pugmill equipment)
GROUP 5: Cast-in-place pipe laying machine; Combination slusher and motor operator; Concrete conveyor or concrete pump, truck or equipment mounted; Concrete conveyor,
building site; Concrete pump or pumpcrete gun; Drilling equipment, Watson 2000, Texoma 700 or similar; Drilling and boring machinery, horizontal (not to apply to waterliners, wagon drills or jackhammers); Concrete mixer/all; Person and/or material hoist; Mechanical finishers (concrete)
(Clary, Johnson, Bidwell Bridge Deck or similar types); Mechanical burm, curb and/or curb and gutter machine,
concrete or asphalt); Mine or shaft hoist; Portable
crusher; Power jumbo operator (setting slip-forms, etc., in tunnels); Screed (automatic or manual); Self-propelled
compactor with dozer; Tractor with boom D6 or smaller;
Trenching machine, maximum digging capacity over 5 ft.
depth; Vermeer T-600B rock cutter or similar
GROUP 6: Armor-Coater (or similar); Ballast jack tamper; Boom- type backfilling machine; Assistant plant engineer; Bridge and/or gantry crane; Chemical grouting machine,
truck-mounted; Chip spreading machine operator; Concrete saw (self-propelled unit on streets, highways, airports and canals); Deck engineer; Drilling equipment Texoma 600,
Hughes 200 Series or similar up to and including 30 ft. m.r.c.; Drill doctor; Helicopter radio operator;
Hydro-hammer or similar; Line master; Skidsteer loader, Bobcat larger than 743 series or similar (with
attachments); Locomotive; Lull hi-lift or similar; Oiler, truck mounted equipment; Pavement breaker, truck-mounted, with compressor combination; Paving fabric installation and/or laying machine; Pipe bending machine (pipelines
only); Pipe wrapping machine (tractor propelled and
supported); Screed (except asphaltic concrete paving);
Self- propelled pipeline wrapping machine; Tractor;
Self-loading chipper; Concrete barrier moving machine
GROUP 7: Ballast regulator; Boom truck or dual-purpose
A-frame truck, non-rotating - under 15 tons; Cary lift or similar; Combination slurry mixer and/or cleaner; Drilling equipment, 20 ft. and under m.r.c.; Firetender (hot plant); Grouting machine operator; Highline cableway signalperson; Stationary belt loader (Kolman or similar); Lift slab
machine (Vagtborg and similar types); Maginnes internal full slab vibrator; Material hoist (1 drum); Mechanical

EXHIBIT D

EXHIBIT 1
trench shield; Pavement breaker with or without compressor combination); Pipe cleaning machine (tractor propelled and supported); Post driver; Roller (except asphalt); Chip
Seal; Self-propelled automatically applied concrete curing mahcine (on streets, highways, airports and canals);
Self-propelled compactor (without dozer); Signalperson; Slip-form pumps (lifting device for concrete forms); Tie spacer; Tower mobile; Trenching machine, maximum digging capacity up to and including 5 ft. depth; Truck- type loader GROUP 8: Bit sharpener; Boiler tender; Box operator;
Brakeperson; Combination mixer and compressor
(shotcrete/gunite); Compressor operator; Deckhand; Fire tender; Forklift (under 20 ft.); Generator;
Gunite/shotcrete equipment operator; Hydraulic monitor; Ken seal machine (or similar); Mixermobile; Oiler; Pump
operator; Refrigeration plant; Reservoir-debris tug (self- propelled floating); Ross Carrier (construction site);
Rotomist operator; Self-propelled tape machine; Shuttlecar; Self-propelled power sweeper operator (includes vacuum
sweeper); Slusher operator; Surface heater; Switchperson; Tar pot firetender; Tugger hoist, single drum; Vacuum
cooling plant; Welding machine (powered other than by
electricity)
GROUP 8-A: Elevator operator; Skidsteer loader-Bobcat 743 series or smaller, and similar (without attachments); Mini excavator under 25 H.P. (backhoe-trencher); Tub grinder wood chipper
----------------------------------------------------------

ALL CRANES AND ATTACHMENTS
GROUP 1: Clamshell and dragline over 7 cu. yds.; Crane, over 100 tons; Derrick, over 100 tons; Derrick barge
pedestal-mounted, over 100 tons; Self-propelled boom-type lifting device, over 100 tons
GROUP 2: Clamshell and dragline over 1 cu. yd. up to and including 7 cu. yds.; Crane, over 45 tons up to and
including 100 tons; Derrick barge, 100 tons and under;
Self-propelled boom-type lifting device, over 45 tons;
Tower crane
GROUP 3: Clamshell and dragline up to and including 1 cu. yd.; Cranes 45 tons and under; Self-propelled boom-type lifting device 45 tons and under;
GROUP 4: Boom Truck or dual purpose A-frame truck,
non-rotating over 15 tons; Truck-mounted rotating
telescopic boom type lifting device, Manitex or similar (boom truck) over 15 tons; Truck-mounted rotating
telescopic boom type lifting device, Manitex or similar (boom truck) - under 15 tons;
-----------------------------------------------------------

PILEDRIVERS
GROUP 1: Derrick barge pedestal mounted over 100 tons;
Clamshell over 7 cu. yds.; Self-propelled boom-type lifting device over 100 tons; Truck crane or crawler, land or barge mounted over 100 tons

EXHIBIT D

EXHIBIT 1
GROUP 2: Derrick barge pedestal mounted 45 tons to and
including 100 tons; Clamshell up to and including 7 cu. yds.; Self-propelled boom-type lifting device over 45 tons; Truck crane or crawler, land or barge mounted, over 45 tons up to and including 100 tons; Fundex F-12 hydraulic pile rig GROUP 3: Derrick barge pedestal mounted under 45 tons; Self- propelled boom-type lifting device 45 tons and under;
Skid/scow piledriver, any tonnage; Truck crane or crawler, land or barge mounted 45 tons and under
GROUP 4: Assistant operator in lieu of assistant to engineer; Forklift, 10 tons and over; Heavy-duty repairperson/welder GROUP 5: Deck engineer
GROUP 6: Deckhand; Fire tender
-------------------------------------------------------------

STEEL ERECTORS
GROUP 1: Crane over 100 tons; Derrick over 100 tons; Self- propelled boom-type lifting device over 100 tons
GROUP 2: Crane over 45 tons to 100 tons; Derrick under 100 tons; Self-propelled boom-type lifting device over 45 tons to 100 tons; Tower crane
GROUP 3: Crane, 45 tons and under; Self-propelled boom-type lifting device, 45 tons and under
GROUP 4: Chicago boom; Forklift, 10 tons and over; Heavy-duty repair person/welder
GROUP 5: Boom cat
-------------------------------------------------------------- --

TUNNEL AND UNDERGROUND WORK
GROUP 1-A: Tunnel bore machine operator, 20' diameter or more

GROUP 1: Heading shield operator; Heavy-duty repairperson; Mucking machine (rubber tired, rail or track type); Raised bore operator (tunnels); Tunnel mole bore operator
GROUP 2: Combination slusher and motor operator; Concrete pump or pumpcrete gun; Power jumbo operator
GROUP 3: Drill doctor; Mine or shaft hoist
GROUP 4: Combination slurry mixer cleaner; Grouting Machine operator; Motorman
GROUP 5: Bit Sharpener; Brakeman; Combination mixer and compressor (gunite); Compressor operator; Oiler; Pump
operator; Slusher operator
----------------------------------------------------------- AREA DESCRIPTIONS:

POWER EQUIPMENT OPERATORS, CRANES AND ATTACHMENTS,TUNNEL AND

EXHIBIT D

EXHIBIT 1
UNDERGROUND [These areas do not apply to Piledrivers and Steel Erectors]
AREA 1: ALAMEDA, CALAVERAS, CONTRA COSTA, FRESNO, KINGS,

MADERA, MARIPOSA, MERCED, MONTEREY, SAN BENITO, SAN

FRANCISCO, SAN JOAQUIN, SAN MATEO, SANTA CLARA, SANTA CRUZ,

STANISLAUS, TUOLUMNE
AREA 2 -NOTED BELOW
THE REMAINING COUNTIES ARE SPLIT BETWEEN AREA 1 AND AREA 2 AS NOTED BELOW:

CALAVERAS COUNTY:

Area 1: Remainder
Area 2: Eastern Part
FRESNO COUNTY:

Area 1: Remainder
Area 2: Eastern Part
MADERA COUNTY:

Area 1: Remainder
Area 2: Eastern Part
MARIPOSA COUNTY:

Area 1: Remainder
Area 2: Eastern Part
MONTEREY COUNTY:

Area 1: Remainder
Area 2: Southwestern part
TUOLUMNE COUNTY:

Area 1: Remainder
Area 2: Eastern Part
---------------------------------------------------------------- ENGI0003-008 08/01/2024
Rates Fringes
Dredging: (DREDGING:

CLAMSHELL & DIPPER DREDGING;
HYDRAULIC SUCTION DREDGING:)
AREA 1:
(1) Leverman...............$ 60.61 39.55
(2) Dredge Dozer; Heavy
duty repairman.............$ 55.65 39.55
(3) Booster Pump
Operator; Deck
Engineer; Deck mate;
Dredge Tender; Winch
Operator...................$ 54.53 39.55
(4) Bargeman; Deckhand;
Fireman; Leveehand; Oiler..$ 51.23 39.55
AREA 2:
(1) Leverman...............$ 62.61 39.55
(2) Dredge Dozer; Heavy
duty repairman.............$ 57.65 39.55
(3) Booster Pump
Operator; Deck
Engineer; Deck mate;
Dredge Tender; Winch
Operator...................$ 56.53 39.55
(4) Bargeman; Deckhand;

EXHIBIT D

EXHIBIT 1
Fireman; Leveehand; Oiler..$ 53.23 39.55

AREA DESCRIPTIONS
AREA 1: ALAMEDA,BUTTE, CONTRA COSTA, KINGS, MARIN, MERCED,

NAPA, SACRAMENTO, SAN BENITO, SAN FRANCISCO, SAN JOAQUIN,

SAN MATEO, SANTA CLARA, SANTA CRUZ, SOLANO, STANISLAUS,

SUTTER, YOLO, AND YUBA COUNTIES
AREA 2: MODOC COUNTY
THE REMAINGING COUNTIES ARE SPLIT BETWEEN AREA 1 AND AREA 2 AS NOTED BELOW:

ALPINE COUNTY:

Area 1: Northernmost part
Area 2: Remainder
CALAVERAS COUNTY:

Area 1: Remainder
Area 2: Eastern part
COLUSA COUNTY:

Area 1: Eastern part
Area 2: Remainder
ELDORADO COUNTY:

Area 1: North Central part
Area 2: Remainder

FRESNO COUNTY:

Area 1: Remainder
Area 2: Eastern part
GLENN COUNTY:

Area 1: Eastern part
Area 2: Remainder
LASSEN COUNTY:

Area 1: Western part along the Southern portion of border with Shasta County
Area 2: Remainder
MADERA COUNTY:

Area 1: Except Eastern part
Area 2: Eastern part

MARIPOSA COUNTY
Area 1: Except Eastern part
Area 2: Eastern part

MONTERREY COUNTY
Area 1: Except Southwestern part
Area 2: Southwestern part
NEVADA COUNTY:

Area 1: All but the Northern portion along the border of Sierra County
Area 2: Remainder
PLACER COUNTY:

Area 1: Al but the Central portion
Area 2: Remainder
PLUMAS COUNTY:

EXHIBIT D

EXHIBIT 1
Area 1: Western portion
Area 2: Remainder
SHASTA COUNTY:

Area 1: All but the Northeastern corner
Area 2: Remainder
SIERRA COUNTY:

Area 1: Western part
Area 2: Remainder
SISKIYOU COUNTY:

Area 1: Central part
Area 2: Remainder
SONOMA COUNTY:

Area 1: All but the Northwestern corner
Area 2: Remainder
TEHAMA COUNTY:

Area 1: All but the Western border with Mendocino & Trinity Counties
Area 2: Remainder
TRINITY COUNTY:

Area 1: East Central part and the Northeastern border with Shasta County
Area 2: Remainder
TUOLUMNE COUNTY:

Area 1: Except Eastern part
Area 2: Eastern part
---------------------------------------------------------------- ENGI0003-019 07/01/2024

SEE AREA DESCRIPTIONS BELOW
Rates Fringes
OPERATOR: Power Equipment
(LANDSCAPE WORK ONLY)
GROUP 1
AREA 1.....................$ 52.40 28.52
AREA 2.....................$ 54.40 28.52
GROUP 2
AREA 1.....................$ 48.80 28.52
AREA 2.....................$ 50.80 28.52
GROUP 3
AREA 1.....................$ 44.19 28.52
AREA 2.....................$ 46.19 28.52
GROUP DESCRIPTIONS:

GROUP 1: Landscape Finish Grade Operator: All finish grade work regardless of equipment used, and all equipment with a rating more than 65 HP.

GROUP 2: Landscape Operator up to 65 HP: All equipment with a manufacturer's rating of 65 HP or less except equipment covered by Group 1 or Group 3. The following equipment shall be included except when used for finish work as long as manufacturer's rating is 65 HP or less: A-Frame and
Winch Truck, Backhoe, Forklift, Hydragraphic Seeder
Machine, Roller, Rubber-Tired and Track Earthmoving

EXHIBIT D

EXHIBIT 1
Equipment, Skiploader, Straw Blowers, and Trencher 31 HP up to 65 HP.

GROUP 3: Landscae Utility Operator: Small Rubber-Tired
Tractor, Trencher Under 31 HP.

AREA DESCRIPTIONS:

AREA 1: ALAMEDA, BUTTE, CONTRA COSTA, KINGS, MARIN, MERCED,

NAPA, SACRAMENTO, SAN BENITO, SAN FRANCISCO, SAN JOAQUIN,

SAN MATEO, SANTA CLARA, SANTA CRUZ, SOLANO, STANISLAUS,

SUTTER, YOLO, AND YUBA COUNTIES
AREA 2 - MODOC COUNTY
THE REMAINING COUNTIES ARE SPLIT BETWEEN AREA 1 AND AREA 2 AS NOTED BELOW:

ALPINE COUNTY:

Area 1: Northernmost part
Area 2: Remainder
CALAVERAS COUNTY:

Area 1: Except Eastern part
Area 2: Eastern part
COLUSA COUNTY:

Area 1: Eastern part
Area 2: Remainder
DEL NORTE COUNTY:

Area 1: Extreme Southwestern corner
Area 2: Remainder
ELDORADO COUNTY:

Area 1: North Central part
Area 2: Remainder

FRESNO COUNTY
Area 1: Except Eastern part
Area 2: Eastern part
GLENN COUNTY:

Area 1: Eastern part
Area 2: Remainder
HUMBOLDT COUNTY:

Area 1: Except Eastern and Southwestern parts
Area 2: Remainder
LAKE COUNTY:

Area 1: Southern part
Area 2: Remainder
LASSEN COUNTY:

Area 1: Western part along the Southern portion of border with Shasta County
Area 2: Remainder

MADERA COUNTY
Area 1: Remainder
Area 2: Eastern part

MARIPOSA COUNTY
Area 1: Remainder

EXHIBIT D

EXHIBIT 1
Area 2: Eastern part
MENDOCINO COUNTY:

Area 1: Central and Southeastern parts
Area 2: Remainder

MONTEREY COUNTY
Area 1: Remainder
Area 2: Southwestern part
NEVADA COUNTY:

Area 1: All but the Northern portion along the border of Sierra County
Area 2: Remainder
PLACER COUNTY:

Area 1: All but the Central portion
Area 2: Remainder
PLUMAS COUNTY:

Area 1: Western portion
Area 2: Remainder
SHASTA COUNTY:

Area 1: All but the Northeastern corner
Area 2: Remainder
SIERRA COUNTY:

Area 1: Western part
Area 2: Remainder
SISKIYOU COUNTY:

Area 1: Central part
Area 2: Remainder
SONOMA COUNTY:

Area 1: All but the Northwestern corner
Area 2: Reaminder
TEHAMA COUNTY:

Area 1: All but the Western border with mendocino & Trinity Counties
Area 2: Remainder
TRINITY COUNTY:

Area 1: East Central part and the Northeaster border with Shasta County
Area 2: Remainder
TULARE COUNTY;
Area 1: Remainder
Area 2: Eastern part
TUOLUMNE COUNTY:

Area 1: Remainder
Area 2: Eastern Part
---------------------------------------------------------------- IRON0377-001 01/01/2025

ALAMEDA, CONTRA COSTA, SAN MATEO, SANTA CLARA COUNTIES
Rates Fringes
Ironworkers:

EXHIBIT D

EXHIBIT 1
Fence Erector...............$ 45.78 26.51
Ornamental, Reinforcing
and Structural..............$ 55.33 35.15
PREMIUM PAY:
$6.00 additional per hour at the following locations:

China Lake Naval Test Station, Chocolate Mountains Naval Reserve-Niland,
Edwards AFB, Fort Irwin Military Station, Fort Irwin Training Center-Goldstone, San Clemente Island, San Nicholas Island, Susanville Federal Prison, 29 Palms - Marine Corps, U.S. Marine Base - Barstow, U.S. Naval Air Facility - Sealey, Vandenberg AFB $4.00 additional per hour at the following locations:

Army Defense Language Institute - Monterey, Fallon Air Base, Naval Post Graduate School - Monterey, Yermo Marine Corps Logistics Center
$2.00 additional per hour at the following locations:

Port Hueneme, Port Mugu, U.S. Coast Guard Station - Two Rock ---------------------------------------------------------------- IRON0377-003 01/01/2025
SAN FRANCISCO CITY and COUNTY
Rates Fringes
Ironworkers:

Fence Erector...............$ 45.78 26.51
Ornamental, Reinforcing
and Structural..............$ 55.83 35.15
PREMIUM PAY:
$6.00 additional per hour at the following locations:

China Lake Naval Test Station, Chocolate Mountains Naval Reserve-Niland,
Edwards AFB, Fort Irwin Military Station, Fort Irwin Training Center-Goldstone, San Clemente Island, San Nicholas Island, Susanville Federal Prison, 29 Palms - Marine Corps, U.S. Marine Base - Barstow, U.S. Naval Air Facility - Sealey, Vandenberg AFB $4.00 additional per hour at the following locations:

Army Defense Language Institute - Monterey, Fallon Air Base, Naval Post Graduate School - Monterey, Yermo Marine Corps Logistics Center
$2.00 additional per hour at the following locations:

Port Hueneme, Port Mugu, U.S. Coast Guard Station - Two Rock ---------------------------------------------------------------- IRON0433-005 01/01/2025

REMAINING COUNTIES

EXHIBIT D

EXHIBIT 1
Rates Fringes

IRONWORKER
Fence Erector...............$ 45.78 26.51
Ornamental, Reinforcing
and Structural..............$ 50.70 35.15
PREMIUM PAY:
$6.00 additional per hour at the following locations:

China Lake Naval Test Station, Chocolate Mountains Naval Reserve-Niland,
Edwards AFB, Fort Irwin Military Station, Fort Irwin Training Center-Goldstone, San Clemente Island, San Nicholas Island, Susanville Federal Prison, 29 Palms - Marine Corps, U.S. Marine Base - Barstow, U.S. Naval Air Facility - Sealey, Vandenberg AFB $4.00 additional per hour at the following locations:

Army Defense Language Institute - Monterey, Fallon Air Base, Naval Post Graduate School - Monterey, Yermo Marine Corps Logistics Center
$2.00 additional per hour at the following locations:

Port Hueneme, Port Mugu, U.S. Coast Guard Station - Two Rock ---------------------------------------------------------------- LABO0067-006 07/01/2024
AREA ""1"" - ALAMEDA, CONTRA COSTA, SAN FRANCISCO, SAN MATEO AND

SANTA CLARA COUNTIES
AREA ""2"" - CALAVERAS, FRESNO, KINGS, MADERA, MARIPOSA,

MERCED, MONTEREY, SAN BENITO, SAN JOAQUIN, STANISLAUS, AND

TUOLUMNE COUNTIES
Rates Fringes

LABORER (ASBESTOS/MOLD/LEAD

LABORER)
Area 1......................$ 37.75 29.69
Area 2......................$ 36.75 29.69
ASBESTOS REMOVAL-SCOPE OF WORK: Site mobilization; initial site clean-up; site preparation; removal of
asbestos-containing materials from walls and ceilings; or from pipes, boilers and mechanical systems only if they are being scrapped; encapsulation, enclosure and disposal of asbestos-containing materials by hand or with equipment or machinery; scaffolding; fabrication of temporary wooden barriers; and assembly of decontamination stations.
---------------------------------------------------------------- LABO0073-002 07/01/2023

CALAVERAS AND SAN JOAQUIN COUNTIES
Rates Fringes

LABORER (TRAFFIC CONTROL/LANE

CLOSURE)

EXHIBIT D

EXHIBIT 1
Escort Driver, Flag Person..$ 36.26 27.30
Traffic Control Person I....$ 36.56 27.30
Traffic Control Person II...$ 34.06 27.30
TRAFFIC CONTROL PERSON I: Layout of traffic control, crash cushions, construction area and roadside signage.

TRAFFIC CONTROL PERSON II: Installation and removal of
temporary/permanent signs, markers, delineators and crash cushions.
---------------------------------------------------------------- LABO0073-003 07/01/2023

SAN JOAQUIN COUNTY
Rates Fringes

LABORER
Mason Tender-Brick..........$ 36.29 25.55
---------------------------------------------------------------- LABO0073-005 06/26/2023
Rates Fringes
Tunnel and Shaft Laborers:

GROUP 1.....................$ 45.89 27.72
GROUP 2.....................$ 45.66 27.72
GROUP 3.....................$ 45.41 27.72
GROUP 4.....................$ 44.96 27.72
GROUP 5.....................$ 44.42 27.72
Shotcrete Specialist........$ 46.41 27.72

TUNNEL AND SHAFT CLASSIFICATIONS
GROUP 1: Diamond driller; Groundmen; Gunite and shotcrete nozzlemen
GROUP 2: Rodmen; Shaft work & raise (below actual or
excavated ground level)
GROUP 3: Bit grinder; Blaster, driller, powdermen, heading; Cherry pickermen - where car is lifted; Concrete finisher in tunnel; Concrete screedman; Grout pumpman and potman; Gunite & shotcrete gunman & potman; Headermen; High
pressure nozzleman; Miner - tunnel, including top and
bottom man on shaft and raise work; Nipper; Nozzleman on slick line; Sandblaster - potman, Robotic Shotcrete Placer, Segment Erector, Tunnel Muck Hauler, Steel Form raiser and setter; Timberman, retimberman (wood or steel or substitute materials therefore); Tugger (for tunnel laborer work); Cable tender; Chuck tender; Powderman - primer house
GROUP 4: Vibrator operator, pavement breaker; Bull gang - muckers, trackmen; Concrete crew - includes rodding and spreading, Dumpmen (any method)
GROUP 5: Grout crew; Reboundman; Swamper/ Brakeman
---------------------------------------------------------------- LABO0073-007 06/26/2023

CALAVERAS AND SAN JOAQUIN COUNTIES
Rates Fringes

EXHIBIT D

EXHIBIT 1

LABORER (CONSTRUCTION CRAFT

LABORERS)
Construction Specialist
Group.......................$ 36.20 27.30
GROUP 1.....................$ 35.50 27.30
GROUP 1-a...................$ 35.72 27.30
GROUP 1-c...................$ 35.55 27.30
GROUP 1-e...................$ 36.05 27.30
GROUP 1-f...................$ 30.37 23.20
GROUP 2.....................$ 35.35 27.30
GROUP 3.....................$ 35.25 27.30
GROUP 4.....................$ 28.94 27.30
See groups 1-b and 1-d under laborer classifications.

LABORER (GARDENERS,

HORTICULTURAL & LANDSCAPE

LABORERS)
(1) New Construction........$ 35.25 27.30
(2) Establishment Warranty
Period......................$ 28.94 27.30

LABORER (GUNITE)
GROUP 1.....................$ 36.46 27.30
GROUP 2.....................$ 35.96 27.30
GROUP 3.....................$ 35.37 27.30
GROUP 4.....................$ 35.25 27.30

LABORER (WRECKING)
GROUP 1.....................$ 35.50 27.30
GROUP 2.....................$ 35.35 27.30
FOOTNOTES:

Laborers working off or with or from bos'n chairs, swinging scaffolds, belts shall receive $0.25 per hour above the applicable wage rate. This shall not apply to workers
entitled to receive the wage rate set forth in Group 1-a below.
---------------------------------------------------------

LABORER CLASSIFICATIONS
CONSTRUCTION SPECIALIST GROUP: Asphalt ironer and raker; Chainsaw; Laser beam in connection with laborers' work; Cast-in- place manhole form setter; Pressure pipelayer; Davis trencher - 300 or similar type (and all small
trenchers); Blaster; Diamond driller; Multiple unit drill; Hydraulic drill
GROUP 1: Asphalt spreader boxes (all types); Barko, Wacker and similar type tampers; Buggymobile; Caulker, bander, pipewrapper, conduit layer, plastic pipelayer; Certified hazardous waste worker including Leade Abatement;
Compactors of all types; Concrete and magnesite mixer, 1/2 yd. and under; Concrete pan work; Concrete sander; Concrete saw; Cribber and/or shoring; Cut granite curb setter;
Dri-pak-it machine; Faller, logloader and bucker; Form
raiser, slip forms; Green cutter; Headerboard, Hubsetter, aligner, by any method; High pressure blow pipe (1-1/2"" or over, 100 lbs. pressure/over); Hydro seeder and similar type; Jackhammer operator; Jacking of pipe over 12 inches; Jackson and similar type compactor; Kettle tender, pot and worker applying asphalt, lay-kold, creosote, lime, caustic and similar type materials (applying means applying,
dipping or handling of such materials); Lagging, sheeting, whaling, bracing, trenchjacking, lagging hammer; Magnesite,

EXHIBIT D

EXHIBIT 1
epoxyresin, fiberglass, mastic worker (wet or dry); No
joint pipe and stripping of same, including repair of
voids; Pavement breaker and spader, including tool grinder; Perma curb; Pipelayer (including grade checking in
connection with pipelaying); Precast-manhole setter;
Pressure pipe tester; Post hole digger, air, gas and
electric; Power broom sweeper; Power tampers of all types (except as shown in Group 2); Ram set gun and stud gun; Riprap stonepaver and rock-slinger, including placing of sacked concrete and/or sand (wet or dry) and gabions and similar type; Rotary scarifier or multiple head concrete chipping scarifier; Roto and Ditch Witch; Rototiller;
Sandblaster, pot, gun, nozzle operators; Signalling and rigging; Tank cleaner; Tree climber; Turbo blaster;
Vibrascreed, bull float in connection with laborers' work; Vibrator; Hazardous waste worker (lead removal); Asbestos and mold removal worker
GROUP 1-a: Joy drill model TWM-2A; Gardner-Denver model DH143 and similar type drills; Track driller; Jack leg driller; Wagon driller; Mechanical drillers, all types regardless of type or method of power; Mechanical pipe layers, all types regardless of type or method of power; Blaster and powder; All work of loading, placing and blasting of all powder and explosives of whatever type regardless of method used for such loading and placing; High scalers (including drilling of same); Tree topper; Bit grinder
GROUP 1-b: Sewer cleaners shall receive $4.00 per day above Group 1 wage rates. ""Sewer cleaner"" means any worker who handles or comes in contact with raw sewage in small
diameter sewers. Those who work inside recently active, large diameter sewers, and all recently active sewer
manholes shal receive $5.00 per day above Group 1 wage
rates.

GROUP 1-c: Burning and welding in connection with laborers' work; Synthetic thermoplastics and similar type welding GROUP 1-d: Maintenance and repair track and road beds. All employees performing work covered herein shall receive $ .25 per hour above their regular rate for all work
performed on underground structures not specifically
covered herein. This paragraph shall not be construed to apply to work below ground level in open cut. It shall apply to cut and cover work of subway construction after the temporary cover has been placed.

GROUP 1-e: Work on and/or in bell hole footings and shafts thereof, and work on and in deep footings. (A deep footing is a hole 15 feet or more in depth.) In the event the
depth of the footing is unknown at the commencement of
excavation, and the final depth exceeds 15 feet, the deep footing wage rate would apply to all employees for each and every day worked on or in the excavation of the footing from the date of inception.

GROUP 1-f: Wire winding machine in connection with guniting or shot crete
GROUP 2: Asphalt shoveler; Cement dumper and handling dry cement or gypsum; Choke-setter and rigger (clearing work); Concrete bucket dumper and chute; Concrete chipping and grinding; Concrete laborer (wet or dry); Driller tender, chuck tender, nipper; Guinea chaser (stake), grout crew;

EXHIBIT D

EXHIBIT 1
High pressure nozzle, adductor; Hydraulic monitor (over 100 lbs. pressure); Loading and unloading, carrying and hauling of all rods and materials for use in reinforcing concrete construction; Pittsburgh chipper and similar type brush shredders; Sloper; Single foot, hand-held, pneumatic
tamper; All pneumatic, air, gas and electric tools not
listed in Groups 1 through 1-f; Jacking of pipe - under 12 inches
GROUP 3: Construction laborers, including bridge and general laborer; Dump, load spotter; Flag person; Fire watcher; Fence erector; Guardrail erector; Gardener, horticultural and landscape laborer; Jetting; Limber, brush loader and piler; Pavement marker (button setter); Maintenance, repair track and road beds; Streetcar and railroad construction track laborer; Temporary air and water lines, Victaulic or similar; Tool room attendant (jobsite only)
GROUP 4: Final clean-up work of debris, grounds and building including but not limited to: street cleaner; cleaning and washing windows; brick cleaner (jobsite only); material cleaner (jobsite only). The classification ""material
cleaner"" is to be utilized under the following conditions:

A: at demolition site for the salvage of the material.

B: at the conclusion of a job where the material is to be salvaged and stocked to be reused on another job.

C: for the cleaning of salvage material at the jobsite or temporary jobsite yard.

The material cleaner classification should not be used in the performance of ""form stripping, cleaning and oiling and moving to the next point of erection"".
--------------------------------------------------------

GUNITE LABORER CLASSIFICATIONS
GROUP 1: Structural Nozzleman
GROUP 2: Nozzleman, Gunman, Potman, Groundman
GROUP 3: Reboundman
GROUP 4: Gunite laborer
----------------------------------------------------------

WRECKING WORK LABORER CLASSIFICATIONS
GROUP 1: Skilled wrecker (removing and salvaging of sash, windows and materials)
GROUP 2: Semi-skilled wrecker (salvaging of other building materials)
---------------------------------------------------------------- LABO0073-009 07/01/2023

CALAVERAS AND SAN JOAQUIN COUNTIES
Rates Fringes
LABORER (Plaster Tender).........$ 39.77 28.54 Work on a swing stage scaffold: $1.00 per hour additional.

EXHIBIT D

EXHIBIT 1
---------------------------------------------------------------- LABO0261-003 07/01/2023

SAN FRANCISCO AND SAN MATEO COUNTIES
Rates Fringes

LABORER (TRAFFIC CONTROL/LANE

CLOSURE)
Escort Driver, Flag Person..$ 37.26 27.30
Traffic Control Person I....$ 37.56 27.30
Traffic Control Person II...$ 35.06 27.30
TRAFFIC CONTROL PERSON I: Layout of traffic control, crash cushions, construction area and roadside signage.

TRAFFIC CONTROL PERSON II: Installation and removal of
temporary/permanent signs, markers, delineators and crash cushions.
---------------------------------------------------------------- LABO0261-005 06/26/2023

SAN FRANCISCO AND SAN MATEO COUNTIES
Rates Fringes
Tunnel and Shaft Laborers:

GROUP 1.....................$ 45.89 27.72
GROUP 2.....................$ 45.66 27.72
GROUP 3.....................$ 45.41 27.72
GROUP 4.....................$ 44.96 27.72
GROUP 5.....................$ 44.42 27.72
Shotcrete Specialist........$ 46.41 27.72

TUNNEL AND SHAFT CLASSIFICATIONS
GROUP 1: Diamond driller; Groundmen; Gunite and shotcrete nozzlemen
GROUP 2: Rodmen; Shaft work & raise (below actual or
excavated ground level)
GROUP 3: Bit grinder; Blaster, driller, powdermen, heading; Cherry pickermen - where car is lifted; Concrete finisher in tunnel; Concrete screedman; Grout pumpman and potman; Gunite & shotcrete gunman & potman; Headermen; High
pressure nozzleman; Miner - tunnel, including top and
bottom man on shaft and raise work; Nipper; Nozzleman on slick line; Sandblaster - potman, Robotic Shotcrete Placer, Segment Erector, Tunnel Muck Hauler, Steel Form raiser and setter; Timberman, retimberman (wood or steel or substitute materials therefore); Tugger (for tunnel laborer work); Cable tender; Chuck tender; Powderman - primer house
GROUP 4: Vibrator operator, pavement breaker; Bull gang - muckers, trackmen; Concrete crew - includes rodding and spreading, Dumpmen (any method)
GROUP 5: Grout crew; Reboundman; Swamper/ Brakeman
---------------------------------------------------------------- LABO0261-009 06/26/2023

SAN FRANCISCO, AND SAN MATEO COUNTIES

EXHIBIT D

EXHIBIT 1
Rates Fringes

LABORER (CONSTRUCTION CRAFT
LABORERS - AREA A:)
Construction Specialist
Group.......................$ 37.20 27.30
GROUP 1.....................$ 36.50 27.30
GROUP 1-a...................$ 36.72 27.30
GROUP 1-c...................$ 36.55 27.30
GROUP 1-e...................$ 37.05 27.30
GROUP 1-f...................$ 31.37 23.20
GROUP 2.....................$ 36.35 27.30
GROUP 3.....................$ 36.25 27.30
GROUP 4.....................$ 29.94 27.30
See groups 1-b and 1-d under laborer classifications.

LABORER (GARDENERS,

HORTICULTURAL & LANDSCAPE
LABORERS - AREA A:)
(1) New Construction........$ 36.25 27.30
(2) Establishment Warranty
Period......................$ 29.94 27.30
LABORER (WRECKING - AREA A:)
GROUP 1.....................$ 36.50 27.30
GROUP 2.....................$ 36.35 27.30
Laborers: (GUNITE - AREA A:)
GROUP 1.....................$ 37.46 27.30
GROUP 2.....................$ 36.96 27.30
GROUP 3.....................$ 36.37 27.30
GROUP 4.....................$ 36.25 27.30
FOOTNOTES:

Laborers working off or with or from bos'n chairs, swinging scaffolds, belts shall receive $0.25 per hour above the applicable wage rate. This shall not apply to workers
entitled to receive the wage rate set forth in Group 1-a below.
---------------------------------------------------------

LABORER CLASSIFICATIONS
CONSTRUCTION SPECIALIST GROUP: Asphalt ironer and raker; Chainsaw; Laser beam in connection with laborers' work; Cast-in- place manhole form setter; Pressure pipelayer; Davis trencher - 300 or similar type (and all small
trenchers); Blaster; Diamond driller; Multiple unit drill; Hydraulic drill
GROUP 1: Asphalt spreader boxes (all types); Barko, Wacker and similar type tampers; Buggymobile; Caulker, bander, pipewrapper, conduit layer, plastic pipelayer; Certified hazardous waste worker including Leade Abatement;
Compactors of all types; Concrete and magnesite mixer, 1/2 yd. and under; Concrete pan work; Concrete sander; Concrete saw; Cribber and/or shoring; Cut granite curb setter;
Dri-pak-it machine; Faller, logloader and bucker; Form
raiser, slip forms; Green cutter; Headerboard, Hubsetter, aligner, by any method; High pressure blow pipe (1-1/2"" or over, 100 lbs. pressure/over); Hydro seeder and similar type; Jackhammer operator; Jacking of pipe over 12 inches; Jackson and similar type compactor; Kettle tender, pot and worker applying asphalt, lay-kold, creosote, lime, caustic and similar type materials (applying means applying,

EXHIBIT D

EXHIBIT 1
dipping or handling of such materials); Lagging, sheeting, whaling, bracing, trenchjacking, lagging hammer; Magnesite, epoxyresin, fiberglass, mastic worker (wet or dry); No
joint pipe and stripping of same, including repair of
voids; Pavement breaker and spader, including tool grinder; Perma curb; Pipelayer (including grade checking in
connection with pipelaying); Precast-manhole setter;
Pressure pipe tester; Post hole digger, air, gas and
electric; Power broom sweeper; Power tampers of all types (except as shown in Group 2); Ram set gun and stud gun; Riprap stonepaver and rock-slinger, including placing of sacked concrete and/or sand (wet or dry) and gabions and similar type; Rotary scarifier or multiple head concrete chipping scarifier; Roto and Ditch Witch; Rototiller;
Sandblaster, pot, gun, nozzle operators; Signalling and rigging; Tank cleaner; Tree climber; Turbo blaster;
Vibrascreed, bull float in connection with laborers' work; Vibrator; Hazardous waste worker (lead removal); Asbestos and mold removal worker
GROUP 1-a: Joy drill model TWM-2A; Gardner-Denver model DH143 and similar type drills; Track driller; Jack leg driller; Wagon driller; Mechanical drillers, all types regardless of type or method of power; Mechanical pipe layers, all types regardless of type or method of power; Blaster and powder; All work of loading, placing and blasting of all powder and explosives of whatever type regardless of method used for such loading and placing; High scalers (including drilling of same); Tree topper; Bit grinder
GROUP 1-b: Sewer cleaners shall receive $4.00 per day above Group 1 wage rates. ""Sewer cleaner"" means any worker who handles or comes in contact with raw sewage in small
diameter sewers. Those who work inside recently active, large diameter sewers, and all recently active sewer
manholes shal receive $5.00 per day above Group 1 wage
rates.

GROUP 1-c: Burning and welding in connection with laborers' work; Synthetic thermoplastics and similar type welding GROUP 1-d: Maintenance and repair track and road beds. All employees performing work covered herein shall receive $ .25 per hour above their regular rate for all work
performed on underground structures not specifically
covered herein. This paragraph shall not be construed to apply to work below ground level in open cut. It shall apply to cut and cover work of subway construction after the temporary cover has been placed.

GROUP 1-e: Work on and/or in bell hole footings and shafts thereof, and work on and in deep footings. (A deep footing is a hole 15 feet or more in depth.) In the event the
depth of the footing is unknown at the commencement of
excavation, and the final depth exceeds 15 feet, the deep footing wage rate would apply to all employees for each and every day worked on or in the excavation of the footing from the date of inception.

GROUP 1-f: Wire winding machine in connection with guniting or shot crete
GROUP 2: Asphalt shoveler; Cement dumper and handling dry cement or gypsum; Choke-setter and rigger (clearing work); Concrete bucket dumper and chute; Concrete chipping and

EXHIBIT D

EXHIBIT 1
grinding; Concrete laborer (wet or dry); Driller tender, chuck tender, nipper; Guinea chaser (stake), grout crew; High pressure nozzle, adductor; Hydraulic monitor (over 100 lbs. pressure); Loading and unloading, carrying and hauling of all rods and materials for use in reinforcing concrete construction; Pittsburgh chipper and similar type brush shredders; Sloper; Single foot, hand-held, pneumatic
tamper; All pneumatic, air, gas and electric tools not
listed in Groups 1 through 1-f; Jacking of pipe - under 12 inches
GROUP 3: Construction laborers, including bridge and general laborer; Dump, load spotter; Flag person; Fire watcher; Fence erector; Guardrail erector; Gardener, horticultural and landscape laborer; Jetting; Limber, brush loader and piler; Pavement marker (button setter); Maintenance, repair track and road beds; Streetcar and railroad construction track laborer; Temporary air and water lines, Victaulic or similar; Tool room attendant (jobsite only)
GROUP 4: Final clean-up work of debris, grounds and building including but not limited to: street cleaner; cleaning and washing windows; brick cleaner (jobsite only); material cleaner (jobsite only). The classification ""material
cleaner"" is to be utilized under the following conditions:

A: at demolition site for the salvage of the material.

B: at the conclusion of a job where the material is to be salvaged and stocked to be reused on another job.

C: for the cleaning of salvage material at the jobsite or temporary jobsite yard.

The material cleaner classification should not be used in the performance of ""form stripping, cleaning and oiling and moving to the next point of erection"".
--------------------------------------------------------

GUNITE LABORER CLASSIFICATIONS
GROUP 1: Structural Nozzleman
GROUP 2: Nozzleman, Gunman, Potman, Groundman
GROUP 3: Reboundman
GROUP 4: Gunite laborer
----------------------------------------------------------

WRECKING WORK LABORER CLASSIFICATIONS
GROUP 1: Skilled wrecker (removing and salvaging of sash, windows and materials)
GROUP 2: Semi-skilled wrecker (salvaging of other building materials)
---------------------------------------------------------------- LABO0261-011 07/01/2023
SAN FRANCISCO AND SAN MATEO COUNTIES:

Rates Fringes
MASON TENDER, BRICK..............$ 37.05 27.45

EXHIBIT D

EXHIBIT 1
FOOTNOTES: Underground work such as sewers, manholes, catch basins, sewer pipes, telephone conduits, tunnels and cut trenches: $5.00 per day additional. Work in live sewage:
$2.50 per day additional.
---------------------------------------------------------------- LABO0261-014 07/01/2023
SAN FRANCISCO AND SAN MATEO COUNTIES:

Rates Fringes
PLASTER TENDER...................$ 41.93 30.32 Work on a swing stage scaffold: $1.00 per hour additional. ---------------------------------------------------------------- LABO0270-003 07/01/2023
AREA A: SANTA CLARA
AREA B: MONTEREY, SAN BENITO AND SANTA CRUZ COUNTIES
Rates Fringes

LABORER (TRAFFIC CONTROL/LANE

CLOSURE)
Escort Driver, Flag Person
Area A.....................$ 37.26 27.30
Area B.....................$ 36.26 27.30
Traffic Control Person I
Area A.....................$ 37.56 27.30
Area B.....................$ 36.56 27.30
Traffic Control Person II
Area A.....................$ 35.06 27.30
Area B.....................$ 34.06 27.30
TRAFFIC CONTROL PERSON I: Layout of traffic control, crash cushions, construction area and roadside signage.

TRAFFIC CONTROL PERSON II: Installation and removal of
temporary/permanent signs, markers, delineators and crash cushions.
---------------------------------------------------------------- LABO0270-004 06/26/2023

MONTEREY, SAN BENITO, SANTA CLARA, AND SANTA CRUZ COUNTIES Rates Fringes
Tunnel and Shaft Laborers:

GROUP 1.....................$ 45.89 27.72
GROUP 2.....................$ 45.66 27.72
GROUP 3.....................$ 45.41 27.72
GROUP 4.....................$ 44.96 27.72
GROUP 5.....................$ 44.42 27.72
Shotcrete Specialist........$ 46.41 27.72

TUNNEL AND SHAFT CLASSIFICATIONS
GROUP 1: Diamond driller; Groundmen; Gunite and shotcrete nozzlemen

EXHIBIT D

EXHIBIT 1
GROUP 2: Rodmen; Shaft work & raise (below actual or
excavated ground level)
GROUP 3: Bit grinder; Blaster, driller, powdermen, heading; Cherry pickermen - where car is lifted; Concrete finisher in tunnel; Concrete screedman; Grout pumpman and potman; Gunite & shotcrete gunman & potman; Headermen; High
pressure nozzleman; Miner - tunnel, including top and
bottom man on shaft and raise work; Nipper; Nozzleman on slick line; Sandblaster - potman, Robotic Shotcrete Placer, Segment Erector, Tunnel Muck Hauler, Steel Form raiser and setter; Timberman, retimberman (wood or steel or substitute materials therefore); Tugger (for tunnel laborer work); Cable tender; Chuck tender; Powderman - primer house
GROUP 4: Vibrator operator, pavement breaker; Bull gang - muckers, trackmen; Concrete crew - includes rodding and spreading, Dumpmen (any method)
GROUP 5: Grout crew; Reboundman; Swamper/ Brakeman
---------------------------------------------------------------- LABO0270-005 07/01/2023

MONTEREY AND SAN BENITO COUNTIES
Rates Fringes

LABORER
Mason Tender-Brick..........$ 36.29 25.55
---------------------------------------------------------------- LABO0270-007 06/26/2023

MONTEREY, SAN BENITO AND SANTA CRUZ COUNTIES
Rates Fringes

LABORER (CONSTRUCTION CRAFT

LABORERS - AREA B)
Construction Specialist
Group.......................$ 36.20 27.30
GROUP 1.....................$ 35.50 27.30
GROUP 1-a...................$ 35.72 27.30
GROUP 1-c...................$ 35.55 27.30
GROUP 1-e...................$ 36.05 27.30
GROUP 1-f...................$ 36.08 27.30
GROUP 2.....................$ 35.35 27.30
GROUP 3.....................$ 35.25 27.30
GROUP 4.....................$ 28.94 27.30
See groups 1-b and 1-d under laborer classifications.

LABORER (GARDENERS,

HORTICULTURAL & LANDSCAPE

LABORERS - AREA B)
(1) New Construction........$ 35.25 27.30
(2) Establishment Warranty
Period......................$ 28.94 27.30

LABORER (GUNITE - AREA B)
GROUP 1.....................$ 36.46 27.30
GROUP 2.....................$ 35.96 27.30
GROUP 3.....................$ 35.37 27.30
GROUP 4.....................$ 35.25 27.30

LABORER (WRECKING - AREA B)
GROUP 1.....................$ 35.50 27.30
GROUP 2.....................$ 35.35 27.30

EXHIBIT D

EXHIBIT 1
FOOTNOTES:

Laborers working off or with or from bos'n chairs, swinging scaffolds, belts shall receive $0.25 per hour above the applicable wage rate. This shall not apply to workers
entitled to receive the wage rate set forth in Group 1-a below.
---------------------------------------------------------

LABORER CLASSIFICATIONS
CONSTRUCTION SPECIALIST GROUP: Asphalt ironer and raker; Chainsaw; Laser beam in connection with laborers' work; Cast-in- place manhole form setter; Pressure pipelayer; Davis trencher - 300 or similar type (and all small
trenchers); Blaster; Diamond driller; Multiple unit drill; Hydraulic drill
GROUP 1: Asphalt spreader boxes (all types); Barko, Wacker and similar type tampers; Buggymobile; Caulker, bander, pipewrapper, conduit layer, plastic pipelayer; Certified hazardous waste worker including Leade Abatement;
Compactors of all types; Concrete and magnesite mixer, 1/2 yd. and under; Concrete pan work; Concrete sander; Concrete saw; Cribber and/or shoring; Cut granite curb setter;
Dri-pak-it machine; Faller, logloader and bucker; Form
raiser, slip forms; Green cutter; Headerboard, Hubsetter, aligner, by any method; High pressure blow pipe (1-1/2"" or over, 100 lbs. pressure/over); Hydro seeder and similar type; Jackhammer operator; Jacking of pipe over 12 inches; Jackson and similar type compactor; Kettle tender, pot and worker applying asphalt, lay-kold, creosote, lime, caustic and similar type materials (applying means applying,
dipping or handling of such materials); Lagging, sheeting, whaling, bracing, trenchjacking, lagging hammer; Magnesite, epoxyresin, fiberglass, mastic worker (wet or dry); No
joint pipe and stripping of same, including repair of
voids; Pavement breaker and spader, including tool grinder; Perma curb; Pipelayer (including grade checking in
connection with pipelaying); Precast-manhole setter;
Pressure pipe tester; Post hole digger, air, gas and
electric; Power broom sweeper; Power tampers of all types (except as shown in Group 2); Ram set gun and stud gun; Riprap stonepaver and rock-slinger, including placing of sacked concrete and/or sand (wet or dry) and gabions and similar type; Rotary scarifier or multiple head concrete chipping scarifier; Roto and Ditch Witch; Rototiller;
Sandblaster, pot, gun, nozzle operators; Signalling and rigging; Tank cleaner; Tree climber; Turbo blaster;
Vibrascreed, bull float in connection with laborers' work; Vibrator; Hazardous waste worker (lead removal); Asbestos and mold removal worker
GROUP 1-a: Joy drill model TWM-2A; Gardner-Denver model DH143 and similar type drills; Track driller; Jack leg driller; Wagon driller; Mechanical drillers, all types regardless of type or method of power; Mechanical pipe layers, all types regardless of type or method of power; Blaster and powder; All work of loading, placing and blasting of all powder and explosives of whatever type regardless of method used for such loading and placing; High scalers (including drilling of same); Tree topper; Bit grinder
GROUP 1-b: Sewer cleaners shall receive $4.00 per day above

EXHIBIT D

EXHIBIT 1
Group 1 wage rates. ""Sewer cleaner"" means any worker who handles or comes in contact with raw sewage in small
diameter sewers. Those who work inside recently active, large diameter sewers, and all recently active sewer
manholes shal receive $5.00 per day above Group 1 wage
rates.

GROUP 1-c: Burning and welding in connection with laborers' work; Synthetic thermoplastics and similar type welding GROUP 1-d: Maintenance and repair track and road beds. All employees performing work covered herein shall receive $ .25 per hour above their regular rate for all work
performed on underground structures not specifically
covered herein. This paragraph shall not be construed to apply to work below ground level in open cut. It shall apply to cut and cover work of subway construction after the temporary cover has been placed.

GROUP 1-e: Work on and/or in bell hole footings and shafts thereof, and work on and in deep footings. (A deep footing is a hole 15 feet or more in depth.) In the event the
depth of the footing is unknown at the commencement of
excavation, and the final depth exceeds 15 feet, the deep footing wage rate would apply to all employees for each and every day worked on or in the excavation of the footing from the date of inception.

GROUP 1-f: Wire winding machine in connection with guniting or shot crete
GROUP 2: Asphalt shoveler; Cement dumper and handling dry cement or gypsum; Choke-setter and rigger (clearing work); Concrete bucket dumper and chute; Concrete chipping and grinding; Concrete laborer (wet or dry); Driller tender, chuck tender, nipper; Guinea chaser (stake), grout crew; High pressure nozzle, adductor; Hydraulic monitor (over 100 lbs. pressure); Loading and unloading, carrying and hauling of all rods and materials for use in reinforcing concrete construction; Pittsburgh chipper and similar type brush shredders; Sloper; Single foot, hand-held, pneumatic
tamper; All pneumatic, air, gas and electric tools not
listed in Groups 1 through 1-f; Jacking of pipe - under 12 inches
GROUP 3: Construction laborers, including bridge and general laborer; Dump, load spotter; Flag person; Fire watcher; Fence erector; Guardrail erector; Gardener, horticultural and landscape laborer; Jetting; Limber, brush loader and piler; Pavement marker (button setter); Maintenance, repair track and road beds; Streetcar and railroad construction track laborer; Temporary air and water lines, Victaulic or similar; Tool room attendant (jobsite only)
GROUP 4: Final clean-up work of debris, grounds and building including but not limited to: street cleaner; cleaning and washing windows; brick cleaner (jobsite only); material cleaner (jobsite only). The classification ""material
cleaner"" is to be utilized under the following conditions:

A: at demolition site for the salvage of the material.

B: at the conclusion of a job where the material is to be salvaged and stocked to be reused on another job.

C: for the cleaning of salvage material at the jobsite or temporary jobsite yard.

EXHIBIT D

EXHIBIT 1
The material cleaner classification should not be used in the performance of ""form stripping, cleaning and oiling and moving to the next point of erection"".
--------------------------------------------------------

GUNITE LABORER CLASSIFICATIONS
GROUP 1: Structural Nozzleman
GROUP 2: Nozzleman, Gunman, Potman, Groundman
GROUP 3: Reboundman
GROUP 4: Gunite laborer
----------------------------------------------------------

WRECKING WORK LABORER CLASSIFICATIONS
GROUP 1: Skilled wrecker (removing and salvaging of sash, windows and materials)
GROUP 2: Semi-skilled wrecker (salvaging of other building materials)
---------------------------------------------------------------- LABO0270-010 06/26/2023

SANTA CLARA COUNTY
Rates Fringes

LABORER (CONSTRUCTION CRAFT
LABORERS - AREA A:)
Construction Specialist
Group.......................$ 37.20 27.30
GROUP 1.....................$ 36.50 27.30
GROUP 1-a...................$ 36.72 27.30
GROUP 1-c...................$ 36.55 27.30
GROUP 1-e...................$ 37.05 27.30
GROUP 1-f...................$ 37.08 27.30
GROUP 2.....................$ 36.35 27.30
GROUP 3.....................$ 36.25 27.30
GROUP 4.....................$ 29.94 27.30
See groups 1-b and 1-d under laborer classifications.

LABORER (GARDENERS,

HORTICULTURAL & LANDSCAPE
LABORERS - AREA A:)
(1) New Construction........$ 36.25 27.30
(2) Establishment Warranty
Period......................$ 29.94 27.30
LABORER (GUNITE - AREA A:)
GROUP 1.....................$ 37.46 27.30
GROUP 2.....................$ 36.96 27.30
GROUP 3.....................$ 36.37 27.30
GROUP 4.....................$ 36.25 27.30
LABORER (WRECKING - AREA A:)
GROUP 1.....................$ 36.50 27.30
GROUP 2.....................$ 36.35 27.30
FOOTNOTES:

Laborers working off or with or from bos'n chairs, swinging scaffolds, belts shall receive $0.25 per hour above the applicable wage rate. This shall not apply to workers

EXHIBIT D

EXHIBIT 1
entitled to receive the wage rate set forth in Group 1-a below.
---------------------------------------------------------

LABORER CLASSIFICATIONS
CONSTRUCTION SPECIALIST GROUP: Asphalt ironer and raker; Chainsaw; Laser beam in connection with laborers' work; Cast-in- place manhole form setter; Pressure pipelayer; Davis trencher - 300 or similar type (and all small
trenchers); Blaster; Diamond driller; Multiple unit drill; Hydraulic drill
GROUP 1: Asphalt spreader boxes (all types); Barko, Wacker and similar type tampers; Buggymobile; Caulker, bander, pipewrapper, conduit layer, plastic pipelayer; Certified hazardous waste worker including Leade Abatement;
Compactors of all types; Concrete and magnesite mixer, 1/2 yd. and under; Concrete pan work; Concrete sander; Concrete saw; Cribber and/or shoring; Cut granite curb setter;
Dri-pak-it machine; Faller, logloader and bucker; Form
raiser, slip forms; Green cutter; Headerboard, Hubsetter, aligner, by any method; High pressure blow pipe (1-1/2"" or over, 100 lbs. pressure/over); Hydro seeder and similar type; Jackhammer operator; Jacking of pipe over 12 inches; Jackson and similar type compactor; Kettle tender, pot and worker applying asphalt, lay-kold, creosote, lime, caustic and similar type materials (applying means applying,
dipping or handling of such materials); Lagging, sheeting, whaling, bracing, trenchjacking, lagging hammer; Magnesite, epoxyresin, fiberglass, mastic worker (wet or dry); No
joint pipe and stripping of same, including repair of
voids; Pavement breaker and spader, including tool grinder; Perma curb; Pipelayer (including grade checking in
connection with pipelaying); Precast-manhole setter;
Pressure pipe tester; Post hole digger, air, gas and
electric; Power broom sweeper; Power tampers of all types (except as shown in Group 2); Ram set gun and stud gun; Riprap stonepaver and rock-slinger, including placing of sacked concrete and/or sand (wet or dry) and gabions and similar type; Rotary scarifier or multiple head concrete chipping scarifier; Roto and Ditch Witch; Rototiller;
Sandblaster, pot, gun, nozzle operators; Signalling and rigging; Tank cleaner; Tree climber; Turbo blaster;
Vibrascreed, bull float in connection with laborers' work; Vibrator; Hazardous waste worker (lead removal); Asbestos and mold removal worker
GROUP 1-a: Joy drill model TWM-2A; Gardner-Denver model DH143 and similar type drills; Track driller; Jack leg driller; Wagon driller; Mechanical drillers, all types regardless of type or method of power; Mechanical pipe layers, all types regardless of type or method of power; Blaster and powder; All work of loading, placing and blasting of all powder and explosives of whatever type regardless of method used for such loading and placing; High scalers (including drilling of same); Tree topper; Bit grinder
GROUP 1-b: Sewer cleaners shall receive $4.00 per day above Group 1 wage rates. ""Sewer cleaner"" means any worker who handles or comes in contact with raw sewage in small
diameter sewers. Those who work inside recently active, large diameter sewers, and all recently active sewer

EXHIBIT D

EXHIBIT 1
manholes shal receive $5.00 per day above Group 1 wage
rates.

GROUP 1-c: Burning and welding in connection with laborers' work; Synthetic thermoplastics and similar type welding GROUP 1-d: Maintenance and repair track and road beds. All employees performing work covered herein shall receive $ .25 per hour above their regular rate for all work
performed on underground structures not specifically
covered herein. This paragraph shall not be construed to apply to work below ground level in open cut. It shall apply to cut and cover work of subway construction after the temporary cover has been placed.

GROUP 1-e: Work on and/or in bell hole footings and shafts thereof, and work on and in deep footings. (A deep footing is a hole 15 feet or more in depth.) In the event the
depth of the footing is unknown at the commencement of
excavation, and the final depth exceeds 15 feet, the deep footing wage rate would apply to all employees for each and every day worked on or in the excavation of the footing from the date of inception.

GROUP 1-f: Wire winding machine in connection with guniting or shot crete
GROUP 2: Asphalt shoveler; Cement dumper and handling dry cement or gypsum; Choke-setter and rigger (clearing work); Concrete bucket dumper and chute; Concrete chipping and grinding; Concrete laborer (wet or dry); Driller tender, chuck tender, nipper; Guinea chaser (stake), grout crew; High pressure nozzle, adductor; Hydraulic monitor (over 100 lbs. pressure); Loading and unloading, carrying and hauling of all rods and materials for use in reinforcing concrete construction; Pittsburgh chipper and similar type brush shredders; Sloper; Single foot, hand-held, pneumatic
tamper; All pneumatic, air, gas and electric tools not
listed in Groups 1 through 1-f; Jacking of pipe - under 12 inches
GROUP 3: Construction laborers, including bridge and general laborer; Dump, load spotter; Flag person; Fire watcher; Fence erector; Guardrail erector; Gardener, horticultural and landscape laborer; Jetting; Limber, brush loader and piler; Pavement marker (button setter); Maintenance, repair track and road beds; Streetcar and railroad construction track laborer; Temporary air and water lines, Victaulic or similar; Tool room attendant (jobsite only)
GROUP 4: Final clean-up work of debris, grounds and building including but not limited to: street cleaner; cleaning and washing windows; brick cleaner (jobsite only); material cleaner (jobsite only). The classification ""material
cleaner"" is to be utilized under the following conditions:

A: at demolition site for the salvage of the material.

B: at the conclusion of a job where the material is to be salvaged and stocked to be reused on another job.

C: for the cleaning of salvage material at the jobsite or temporary jobsite yard.

The material cleaner classification should not be used in the performance of ""form stripping, cleaning and oiling and moving to the next point of erection"".

EXHIBIT D

EXHIBIT 1
--------------------------------------------------------

GUNITE LABORER CLASSIFICATIONS
GROUP 1: Structural Nozzleman
GROUP 2: Nozzleman, Gunman, Potman, Groundman
GROUP 3: Reboundman
GROUP 4: Gunite laborer
----------------------------------------------------------

WRECKING WORK LABORER CLASSIFICATIONS
GROUP 1: Skilled wrecker (removing and salvaging of sash, windows and materials)
GROUP 2: Semi-skilled wrecker (salvaging of other building materials)
---------------------------------------------------------------- LABO0270-011 07/01/2023

MONTEREY, SAN BENITO, SANTA CRUZ, SANTA CLARA COUNTIES
Rates Fringes
LABORER (Plaster Tender).........$ 40.68 29.68 Work on a swing stage scaffold: $1.00 per hour additional. ---------------------------------------------------------------- LABO0294-001 07/01/2023

FRESNO, KINGS AND MADERA COUNTIES
Rates Fringes
LABORER (Brick)
Mason Tender-Brick..........$ 36.29 25.55
---------------------------------------------------------------- LABO0294-002 07/01/2023

FRESNO, KINGS, AND MADERA COUNTIES
Rates Fringes

LABORER (TRAFFIC CONTROL/LANE

CLOSURE)
Escort Driver, Flag Person..$ 36.26 27.30
Traffic Control Person I....$ 36.56 27.30
Traffic Control Person II...$ 34.06 27.30
TRAFFIC CONTROL PERSON I: Layout of traffic control, crash cushions, construction area and roadside signage.

TRAFFIC CONTROL PERSON II: Installation and removal of
temporary/permanent signs, markers, delineators and crash cushions.
---------------------------------------------------------------- LABO0294-005 06/26/2023

FRESNO, KINGS, AND MADERA COUNTIES

EXHIBIT D

EXHIBIT 1
Rates Fringes
Tunnel and Shaft Laborers:

GROUP 1.....................$ 45.89 27.72
GROUP 2.....................$ 45.66 27.72
GROUP 3.....................$ 45.41 27.72
GROUP 4.....................$ 44.96 27.72
GROUP 5.....................$ 44.42 27.72
Shotcrete Specialist........$ 46.41 27.72

TUNNEL AND SHAFT CLASSIFICATIONS
GROUP 1: Diamond driller; Groundmen; Gunite and shotcrete nozzlemen
GROUP 2: Rodmen; Shaft work & raise (below actual or
excavated ground level)
GROUP 3: Bit grinder; Blaster, driller, powdermen, heading; Cherry pickermen - where car is lifted; Concrete finisher in tunnel; Concrete screedman; Grout pumpman and potman; Gunite & shotcrete gunman & potman; Headermen; High
pressure nozzleman; Miner - tunnel, including top and
bottom man on shaft and raise work; Nipper; Nozzleman on slick line; Sandblaster - potman, Robotic Shotcrete Placer, Segment Erector, Tunnel Muck Hauler, Steel Form raiser and setter; Timberman, retimberman (wood or steel or substitute materials therefore); Tugger (for tunnel laborer work); Cable tender; Chuck tender; Powderman - primer house
GROUP 4: Vibrator operator, pavement breaker; Bull gang - muckers, trackmen; Concrete crew - includes rodding and spreading, Dumpmen (any method)
GROUP 5: Grout crew; Reboundman; Swamper/ Brakeman
---------------------------------------------------------------- LABO0294-008 06/26/2023

FRESNO, KINGS, AND MADERA COUNTIES
Rates Fringes

LABORER (CONSTRUCTION CRAFT
LABORERS - AREA B:)
Construction Specialist
Group.......................$ 36.20 27.30
GROUP 1.....................$ 35.50 27.30
GROUP 1-a...................$ 35.72 27.30
GROUP 1-c...................$ 35.55 27.30
GROUP 1-e...................$ 36.05 27.30
GROUP 1-f...................$ 36.08 27.30
GROUP 2.....................$ 35.35 27.30
GROUP 3.....................$ 35.25 27.30
GROUP 4.....................$ 28.94 27.30
See groups 1-b and 1-d under laborer classifications.

LABORER (GARDENERS,

HORTICULTURAL & LANDSCAPE
LABORERS - AREA B:)
(1) New Construction........$ 35.25 27.30
(2) Establishment Warranty
Period......................$ 28.94 27.30
LABORER (GUNITE - AREA B:)
GROUP 1.....................$ 36.46 27.30

EXHIBIT D

EXHIBIT 1
GROUP 2.....................$ 35.96 27.30
GROUP 3.....................$ 35.37 27.30
GROUP 4.....................$ 35.25 27.30
LABORER (WRECKING - AREA B:)
GROUP 1.....................$ 35.50 27.30
GROUP 2.....................$ 35.35 27.30
FOOTNOTES:

Laborers working off or with or from bos'n chairs, swinging scaffolds, belts shall receive $0.25 per hour above the applicable wage rate. This shall not apply to workers
entitled to receive the wage rate set forth in Group 1-a below.
---------------------------------------------------------

LABORER CLASSIFICATIONS
CONSTRUCTION SPECIALIST GROUP: Asphalt ironer and raker; Chainsaw; Laser beam in connection with laborers' work; Cast-in- place manhole form setter; Pressure pipelayer; Davis trencher - 300 or similar type (and all small
trenchers); Blaster; Diamond driller; Multiple unit drill; Hydraulic drill
GROUP 1: Asphalt spreader boxes (all types); Barko, Wacker and similar type tampers; Buggymobile; Caulker, bander, pipewrapper, conduit layer, plastic pipelayer; Certified hazardous waste worker including Leade Abatement;
Compactors of all types; Concrete and magnesite mixer, 1/2 yd. and under; Concrete pan work; Concrete sander; Concrete saw; Cribber and/or shoring; Cut granite curb setter;
Dri-pak-it machine; Faller, logloader and bucker; Form
raiser, slip forms; Green cutter; Headerboard, Hubsetter, aligner, by any method; High pressure blow pipe (1-1/2"" or over, 100 lbs. pressure/over); Hydro seeder and similar type; Jackhammer operator; Jacking of pipe over 12 inches; Jackson and similar type compactor; Kettle tender, pot and worker applying asphalt, lay-kold, creosote, lime, caustic and similar type materials (applying means applying,
dipping or handling of such materials); Lagging, sheeting, whaling, bracing, trenchjacking, lagging hammer; Magnesite, epoxyresin, fiberglass, mastic worker (wet or dry); No
joint pipe and stripping of same, including repair of
voids; Pavement breaker and spader, including tool grinder; Perma curb; Pipelayer (including grade checking in
connection with pipelaying); Precast-manhole setter;
Pressure pipe tester; Post hole digger, air, gas and
electric; Power broom sweeper; Power tampers of all types (except as shown in Group 2); Ram set gun and stud gun; Riprap stonepaver and rock-slinger, including placing of sacked concrete and/or sand (wet or dry) and gabions and similar type; Rotary scarifier or multiple head concrete chipping scarifier; Roto and Ditch Witch; Rototiller;
Sandblaster, pot, gun, nozzle operators; Signalling and rigging; Tank cleaner; Tree climber; Turbo blaster;
Vibrascreed, bull float in connection with laborers' work; Vibrator; Hazardous waste worker (lead removal); Asbestos and mold removal worker
GROUP 1-a: Joy drill model TWM-2A; Gardner-Denver model DH143 and similar type drills; Track driller; Jack leg driller; Wagon driller; Mechanical drillers, all types regardless of type or method of power; Mechanical pipe layers, all types

EXHIBIT D

EXHIBIT 1
regardless of type or method of power; Blaster and powder; All work of loading, placing and blasting of all powder and explosives of whatever type regardless of method used for such loading and placing; High scalers (including drilling of same); Tree topper; Bit grinder
GROUP 1-b: Sewer cleaners shall receive $4.00 per day above Group 1 wage rates. ""Sewer cleaner"" means any worker who handles or comes in contact with raw sewage in small
diameter sewers. Those who work inside recently active, large diameter sewers, and all recently active sewer
manholes shal receive $5.00 per day above Group 1 wage
rates.

GROUP 1-c: Burning and welding in connection with laborers' work; Synthetic thermoplastics and similar type welding GROUP 1-d: Maintenance and repair track and road beds. All employees performing work covered herein shall receive $ .25 per hour above their regular rate for all work
performed on underground structures not specifically
covered herein. This paragraph shall not be construed to apply to work below ground level in open cut. It shall apply to cut and cover work of subway construction after the temporary cover has been placed.

GROUP 1-e: Work on and/or in bell hole footings and shafts thereof, and work on and in deep footings. (A deep footing is a hole 15 feet or more in depth.) In the event the
depth of the footing is unknown at the commencement of
excavation, and the final depth exceeds 15 feet, the deep footing wage rate would apply to all employees for each and every day worked on or in the excavation of the footing from the date of inception.

GROUP 1-f: Wire winding machine in connection with guniting or shot crete
GROUP 2: Asphalt shoveler; Cement dumper and handling dry cement or gypsum; Choke-setter and rigger (clearing work); Concrete bucket dumper and chute; Concrete chipping and grinding; Concrete laborer (wet or dry); Driller tender, chuck tender, nipper; Guinea chaser (stake), grout crew; High pressure nozzle, adductor; Hydraulic monitor (over 100 lbs. pressure); Loading and unloading, carrying and hauling of all rods and materials for use in reinforcing concrete construction; Pittsburgh chipper and similar type brush shredders; Sloper; Single foot, hand-held, pneumatic
tamper; All pneumatic, air, gas and electric tools not
listed in Groups 1 through 1-f; Jacking of pipe - under 12 inches
GROUP 3: Construction laborers, including bridge and general laborer; Dump, load spotter; Flag person; Fire watcher; Fence erector; Guardrail erector; Gardener, horticultural and landscape laborer; Jetting; Limber, brush loader and piler; Pavement marker (button setter); Maintenance, repair track and road beds; Streetcar and railroad construction track laborer; Temporary air and water lines, Victaulic or similar; Tool room attendant (jobsite only)
GROUP 4: Final clean-up work of debris, grounds and building including but not limited to: street cleaner; cleaning and washing windows; brick cleaner (jobsite only); material cleaner (jobsite only). The classification ""material

EXHIBIT D

EXHIBIT 1
cleaner"" is to be utilized under the following conditions:

A: at demolition site for the salvage of the material.

B: at the conclusion of a job where the material is to be salvaged and stocked to be reused on another job.

C: for the cleaning of salvage material at the jobsite or temporary jobsite yard.

The material cleaner classification should not be used in the performance of ""form stripping, cleaning and oiling and moving to the next point of erection"".
--------------------------------------------------------

GUNITE LABORER CLASSIFICATIONS
GROUP 1: Structural Nozzleman
GROUP 2: Nozzleman, Gunman, Potman, Groundman
GROUP 3: Reboundman
GROUP 4: Gunite laborer
----------------------------------------------------------

WRECKING WORK LABORER CLASSIFICATIONS
GROUP 1: Skilled wrecker (removing and salvaging of sash, windows and materials)
GROUP 2: Semi-skilled wrecker (salvaging of other building materials)
---------------------------------------------------------------- LABO0294-010 07/01/2023

CALAVERAS, FRESNO, KINGS, MADERA, MARIPOSA, MERCED, SAN

JOAQUIN, STANISLAUS & TUOLUMNE
Rates Fringes
Plasterer tender.................$ 39.77 28.54 Work on a swing stage scaffold: $1.00 per hour additional. ---------------------------------------------------------------- LABO0294-011 07/01/2023

FRESNO, KINGS, AND MADERA COUNTIES
Rates Fringes
LABORER (Plaster Tender).........$ 39.77 28.54 Work on a swing stage scaffold: $1.00 per hour additional. ---------------------------------------------------------------- LABO0304-002 07/01/2023

ALAMEDA COUNTY
Rates Fringes

LABORER (TRAFFIC CONTROL/LANE

CLOSURE)
Escort Driver, Flag Person..$ 37.26 27.30

EXHIBIT D

EXHIBIT 1
Traffic Control Person I....$ 37.56 27.30
Traffic Control Person II...$ 35.06 27.30
TRAFFIC CONTROL PERSON I: Layout of traffic control, crash cushions, construction area and roadside signage.

TRAFFIC CONTROL PERSON II: Installation and removal of
temporary/permanent signs, markers, delineators and crash cushions.
---------------------------------------------------------------- LABO0304-003 06/26/2023

ALAMEDA COUNTY
Rates Fringes
Tunnel and Shaft Laborers:

GROUP 1.....................$ 45.89 27.72
GROUP 2.....................$ 45.66 27.72
GROUP 3.....................$ 45.41 27.72
GROUP 4.....................$ 44.96 27.72
GROUP 5.....................$ 44.42 27.72
Shotcrete Specialist........$ 46.41 27.72

TUNNEL AND SHAFT CLASSIFICATIONS
GROUP 1: Diamond driller; Groundmen; Gunite and shotcrete nozzlemen
GROUP 2: Rodmen; Shaft work & raise (below actual or
excavated ground level)
GROUP 3: Bit grinder; Blaster, driller, powdermen, heading; Cherry pickermen - where car is lifted; Concrete finisher in tunnel; Concrete screedman; Grout pumpman and potman; Gunite & shotcrete gunman & potman; Headermen; High
pressure nozzleman; Miner - tunnel, including top and
bottom man on shaft and raise work; Nipper; Nozzleman on slick line; Sandblaster - potman, Robotic Shotcrete Placer, Segment Erector, Tunnel Muck Hauler, Steel Form raiser and setter; Timberman, retimberman (wood or steel or substitute materials therefore); Tugger (for tunnel laborer work); Cable tender; Chuck tender; Powderman - primer house
GROUP 4: Vibrator operator, pavement breaker; Bull gang - muckers, trackmen; Concrete crew - includes rodding and spreading, Dumpmen (any method)
GROUP 5: Grout crew; Reboundman; Swamper/ Brakeman
---------------------------------------------------------------- LABO0304-004 06/26/2023

ALAMEDA COUNTY
Rates Fringes

LABORER (CONSTRUCTION CRAFT
LABORERS - AREA A:)
Construction Specialist
Group.......................$ 37.20 27.30
GROUP 1.....................$ 36.50 27.30
GROUP 1-a...................$ 36.72 27.30
GROUP 1-c...................$ 36.55 27.30

EXHIBIT D

EXHIBIT 1
GROUP 1-e...................$ 37.05 27.30
GROUP 1-f...................$ 37.08 27.30
GROUP 2.....................$ 36.35 27.30
GROUP 3.....................$ 36.25 27.30
GROUP 4.....................$ 29.94 27.30
See groups 1-b and 1-d under laborer classifications.

LABORER (GARDENERS,

HORTICULTURAL & LANDSCAPE
LABORERS - AREA A:)
(1) New Construction........$ 36.25 27.30
(2) Establishment Warranty
Period......................$ 29.94 27.30
LABORER (GUNITE - AREA A:)
GROUP 1.....................$ 37.46 27.30
GROUP 2.....................$ 36.96 27.30
GROUP 3.....................$ 36.37 27.30
GROUP 4.....................$ 36.25 27.30
LABORER (WRECKING - AREA A:)
GROUP 1.....................$ 36.50 27.30
GROUP 2.....................$ 36.35 27.30
FOOTNOTES:

Laborers working off or with or from bos'n chairs, swinging scaffolds, belts shall receive $0.25 per hour above the applicable wage rate. This shall not apply to workers
entitled to receive the wage rate set forth in Group 1-a below.
---------------------------------------------------------

LABORER CLASSIFICATIONS
CONSTRUCTION SPECIALIST GROUP: Asphalt ironer and raker; Chainsaw; Laser beam in connection with laborers' work; Cast-in- place manhole form setter; Pressure pipelayer; Davis trencher - 300 or similar type (and all small
trenchers); Blaster; Diamond driller; Multiple unit drill; Hydraulic drill
GROUP 1: Asphalt spreader boxes (all types); Barko, Wacker and similar type tampers; Buggymobile; Caulker, bander, pipewrapper, conduit layer, plastic pipelayer; Certified hazardous waste worker including Leade Abatement;
Compactors of all types; Concrete and magnesite mixer, 1/2 yd. and under; Concrete pan work; Concrete sander; Concrete saw; Cribber and/or shoring; Cut granite curb setter;
Dri-pak-it machine; Faller, logloader and bucker; Form
raiser, slip forms; Green cutter; Headerboard, Hubsetter, aligner, by any method; High pressure blow pipe (1-1/2"" or over, 100 lbs. pressure/over); Hydro seeder and similar type; Jackhammer operator; Jacking of pipe over 12 inches; Jackson and similar type compactor; Kettle tender, pot and worker applying asphalt, lay-kold, creosote, lime, caustic and similar type materials (applying means applying,
dipping or handling of such materials); Lagging, sheeting, whaling, bracing, trenchjacking, lagging hammer; Magnesite, epoxyresin, fiberglass, mastic worker (wet or dry); No
joint pipe and stripping of same, including repair of
voids; Pavement breaker and spader, including tool grinder; Perma curb; Pipelayer (including grade checking in
connection with pipelaying); Precast-manhole setter;
Pressure pipe tester; Post hole digger, air, gas and
electric; Power broom sweeper; Power tampers of all types (except as shown in Group 2); Ram set gun and stud gun;

EXHIBIT D

EXHIBIT 1
Riprap stonepaver and rock-slinger, including placing of sacked concrete and/or sand (wet or dry) and gabions and similar type; Rotary scarifier or multiple head concrete chipping scarifier; Roto and Ditch Witch; Rototiller;
Sandblaster, pot, gun, nozzle operators; Signalling and rigging; Tank cleaner; Tree climber; Turbo blaster;
Vibrascreed, bull float in connection with laborers' work; Vibrator; Hazardous waste worker (lead removal); Asbestos and mold removal worker
GROUP 1-a: Joy drill model TWM-2A; Gardner-Denver model DH143 and similar type drills; Track driller; Jack leg driller; Wagon driller; Mechanical drillers, all types regardless of type or method of power; Mechanical pipe layers, all types regardless of type or method of power; Blaster and powder; All work of loading, placing and blasting of all powder and explosives of whatever type regardless of method used for such loading and placing; High scalers (including drilling of same); Tree topper; Bit grinder
GROUP 1-b: Sewer cleaners shall receive $4.00 per day above Group 1 wage rates. ""Sewer cleaner"" means any worker who handles or comes in contact with raw sewage in small
diameter sewers. Those who work inside recently active, large diameter sewers, and all recently active sewer
manholes shal receive $5.00 per day above Group 1 wage
rates.

GROUP 1-c: Burning and welding in connection with laborers' work; Synthetic thermoplastics and similar type welding GROUP 1-d: Maintenance and repair track and road beds. All employees performing work covered herein shall receive $ .25 per hour above their regular rate for all work
performed on underground structures not specifically
covered herein. This paragraph shall not be construed to apply to work below ground level in open cut. It shall apply to cut and cover work of subway construction after the temporary cover has been placed.

GROUP 1-e: Work on and/or in bell hole footings and shafts thereof, and work on and in deep footings. (A deep footing is a hole 15 feet or more in depth.) In the event the
depth of the footing is unknown at the commencement of
excavation, and the final depth exceeds 15 feet, the deep footing wage rate would apply to all employees for each and every day worked on or in the excavation of the footing from the date of inception.

GROUP 1-f: Wire winding machine in connection with guniting or shot crete
GROUP 2: Asphalt shoveler; Cement dumper and handling dry cement or gypsum; Choke-setter and rigger (clearing work); Concrete bucket dumper and chute; Concrete chipping and grinding; Concrete laborer (wet or dry); Driller tender, chuck tender, nipper; Guinea chaser (stake), grout crew; High pressure nozzle, adductor; Hydraulic monitor (over 100 lbs. pressure); Loading and unloading, carrying and hauling of all rods and materials for use in reinforcing concrete construction; Pittsburgh chipper and similar type brush shredders; Sloper; Single foot, hand-held, pneumatic
tamper; All pneumatic, air, gas and electric tools not
listed in Groups 1 through 1-f; Jacking of pipe - under 12 inches

EXHIBIT D

EXHIBIT 1
GROUP 3: Construction laborers, including bridge and general laborer; Dump, load spotter; Flag person; Fire watcher; Fence erector; Guardrail erector; Gardener, horticultural and landscape laborer; Jetting; Limber, brush loader and piler; Pavement marker (button setter); Maintenance, repair track and road beds; Streetcar and railroad construction track laborer; Temporary air and water lines, Victaulic or similar; Tool room attendant (jobsite only)
GROUP 4: Final clean-up work of debris, grounds and building including but not limited to: street cleaner; cleaning and washing windows; brick cleaner (jobsite only); material cleaner (jobsite only). The classification ""material
cleaner"" is to be utilized under the following conditions:

A: at demolition site for the salvage of the material.

B: at the conclusion of a job where the material is to be salvaged and stocked to be reused on another job.

C: for the cleaning of salvage material at the jobsite or temporary jobsite yard.

The material cleaner classification should not be used in the performance of ""form stripping, cleaning and oiling and moving to the next point of erection"".
--------------------------------------------------------

GUNITE LABORER CLASSIFICATIONS
GROUP 1: Structural Nozzleman
GROUP 2: Nozzleman, Gunman, Potman, Groundman
GROUP 3: Reboundman
GROUP 4: Gunite laborer
----------------------------------------------------------

WRECKING WORK LABORER CLASSIFICATIONS
GROUP 1: Skilled wrecker (removing and salvaging of sash, windows and materials)
GROUP 2: Semi-skilled wrecker (salvaging of other building materials)
---------------------------------------------------------------- LABO0304-005 07/01/2023

ALAMEDA COUNTY
Rates Fringes
Brick Tender.....................$ 37.05 27.45 FOOTNOTES: Work on jobs where heat-protective clothing is required: $2.00 per hour additional. Work at grinders: $.25 per hour additional. Manhole work: $2.00 per day additional. ---------------------------------------------------------------- LABO0304-008 07/01/2023
ALAMEDA AND CONTRA COSTA COUNTIES:

EXHIBIT D

EXHIBIT 1
Rates Fringes
Plasterer tender.................$ 41.93 30.32 Work on a swing stage scaffold: $1.00 per hour additional. ---------------------------------------------------------------- LABO0324-002 07/01/2023

CONTRA COSTA COUNTY
Rates Fringes

LABORER (TRAFFIC CONTROL/LANE

CLOSURE)
Escort Driver, Flag Person..$ 37.26 27.30
Traffic Control Person I....$ 37.56 27.30
Traffic Control Person II...$ 35.06 27.30
TRAFFIC CONTROL PERSON I: Layout of traffic control, crash cushions, construction area and roadside signage.

TRAFFIC CONTROL PERSON II: Installation and removal of
temporary/permanent signs, markers, delineators and crash cushions.
---------------------------------------------------------------- LABO0324-006 06/26/2023

CONTRA COSTA COUNTY
Rates Fringes
Tunnel and Shaft Laborers:

GROUP 1.....................$ 45.89 27.72
GROUP 2.....................$ 45.66 27.72
GROUP 3.....................$ 45.41 27.72
GROUP 4.....................$ 44.96 27.72
GROUP 5.....................$ 44.42 27.72
Shotcrete Specialist........$ 46.41 27.72

TUNNEL AND SHAFT CLASSIFICATIONS
GROUP 1: Diamond driller; Groundmen; Gunite and shotcrete nozzlemen
GROUP 2: Rodmen; Shaft work & raise (below actual or
excavated ground level)
GROUP 3: Bit grinder; Blaster, driller, powdermen, heading; Cherry pickermen - where car is lifted; Concrete finisher in tunnel; Concrete screedman; Grout pumpman and potman; Gunite & shotcrete gunman & potman; Headermen; High
pressure nozzleman; Miner - tunnel, including top and
bottom man on shaft and raise work; Nipper; Nozzleman on slick line; Sandblaster - potman, Robotic Shotcrete Placer, Segment Erector, Tunnel Muck Hauler, Steel Form raiser and setter; Timberman, retimberman (wood or steel or substitute materials therefore); Tugger (for tunnel laborer work); Cable tender; Chuck tender; Powderman - primer house
GROUP 4: Vibrator operator, pavement breaker; Bull gang - muckers, trackmen; Concrete crew - includes rodding and spreading, Dumpmen (any method)
GROUP 5: Grout crew; Reboundman; Swamper/ Brakeman

EXHIBIT D

EXHIBIT 1
---------------------------------------------------------------- LABO0324-012 06/26/2023

CONTRA COSTA COUNTY
Rates Fringes

LABORER (CONSTRUCTION CRAFT
LABORERS - AREA A:)
Construction Specialist
Group.......................$ 37.20 27.30
GROUP 1.....................$ 36.50 27.30
GROUP 1-a...................$ 36.72 27.30
GROUP 1-c...................$ 36.55 27.30
GROUP 1-e...................$ 37.05 27.30
GROUP 1-f...................$ 37.08 27.30
GROUP 1-g...................$ 36.70 27.30
GROUP 2.....................$ 36.35 27.30
GROUP 3.....................$ 36.25 27.30
GROUP 4.....................$ 29.94 27.30
See groups 1-b and 1-d under laborer classifications.

LABORER (GARDENERS,

HORTICULURAL & LANDSCAPE
LABORERS - AREA A:)
(1) New Construction........$ 36.25 27.30
(2) Establishment Warranty
Period......................$ 29.94 27.30
LABORER (GUNITE - AREA A:)
GROUP 1.....................$ 37.46 27.30
GROUP 2.....................$ 36.96 27.30
GROUP 3.....................$ 36.37 27.30
GROUP 4.....................$ 36.25 27.30
LABORER (WRECKING - AREA A:)
GROUP 1.....................$ 36.50 27.30
GROUP 2.....................$ 36.35 27.30
FOOTNOTES:

Laborers working off or with or from bos'n chairs, swinging scaffolds, belts shall receive $0.25 per hour above the applicable wage rate. This shall not apply to workers
entitled to receive the wage rate set forth in Group 1-a below.
---------------------------------------------------------

LABORER CLASSIFICATIONS
CONSTRUCTION SPECIALIST GROUP: Asphalt ironer and raker; Chainsaw; Laser beam in connection with laborers' work; Cast-in- place manhole form setter; Pressure pipelayer; Davis trencher - 300 or similar type (and all small
trenchers); Blaster; Diamond driller; Multiple unit drill; Hydraulic drill
GROUP 1: Asphalt spreader boxes (all types); Barko, Wacker and similar type tampers; Buggymobile; Caulker, bander, pipewrapper, conduit layer, plastic pipelayer; Certified hazardous waste worker including Leade Abatement;
Compactors of all types; Concrete and magnesite mixer, 1/2 yd. and under; Concrete pan work; Concrete sander; Concrete saw; Cribber and/or shoring; Cut granite curb setter;
Dri-pak-it machine; Faller, logloader and bucker; Form
raiser, slip forms; Green cutter; Headerboard, Hubsetter,

EXHIBIT D

EXHIBIT 1
aligner, by any method; High pressure blow pipe (1-1/2"" or over, 100 lbs. pressure/over); Hydro seeder and similar type; Jackhammer operator; Jacking of pipe over 12 inches; Jackson and similar type compactor; Kettle tender, pot and worker applying asphalt, lay-kold, creosote, lime, caustic and similar type materials (applying means applying,
dipping or handling of such materials); Lagging, sheeting, whaling, bracing, trenchjacking, lagging hammer; Magnesite, epoxyresin, fiberglass, mastic worker (wet or dry); No
joint pipe and stripping of same, including repair of
voids; Pavement breaker and spader, including tool grinder; Perma curb; Pipelayer (including grade checking in
connection with pipelaying); Precast-manhole setter;
Pressure pipe tester; Post hole digger, air, gas and
electric; Power broom sweeper; Power tampers of all types (except as shown in Group 2); Ram set gun and stud gun; Riprap stonepaver and rock-slinger, including placing of sacked concrete and/or sand (wet or dry) and gabions and similar type; Rotary scarifier or multiple head concrete chipping scarifier; Roto and Ditch Witch; Rototiller;
Sandblaster, pot, gun, nozzle operators; Signalling and rigging; Tank cleaner; Tree climber; Turbo blaster;
Vibrascreed, bull float in connection with laborers' work; Vibrator; Hazardous waste worker (lead removal); Asbestos and mold removal worker
GROUP 1-a: Joy drill model TWM-2A; Gardner-Denver model DH143 and similar type drills; Track driller; Jack leg driller; Wagon driller; Mechanical drillers, all types regardless of type or method of power; Mechanical pipe layers, all types regardless of type or method of power; Blaster and powder; All work of loading, placing and blasting of all powder and explosives of whatever type regardless of method used for such loading and placing; High scalers (including drilling of same); Tree topper; Bit grinder
GROUP 1-b: Sewer cleaners shall receive $4.00 per day above Group 1 wage rates. ""Sewer cleaner"" means any worker who handles or comes in contact with raw sewage in small
diameter sewers. Those who work inside recently active, large diameter sewers, and all recently active sewer
manholes shal receive $5.00 per day above Group 1 wage
rates.

GROUP 1-c: Burning and welding in connection with laborers' work; Synthetic thermoplastics and similar type welding GROUP 1-d: Maintenance and repair track and road beds. All employees performing work covered herein shall receive $ .25 per hour above their regular rate for all work
performed on underground structures not specifically
covered herein. This paragraph shall not be construed to apply to work below ground level in open cut. It shall apply to cut and cover work of subway construction after the temporary cover has been placed.

GROUP 1-e: Work on and/or in bell hole footings and shafts thereof, and work on and in deep footings. (A deep footing is a hole 15 feet or more in depth.) In the event the
depth of the footing is unknown at the commencement of
excavation, and the final depth exceeds 15 feet, the deep footing wage rate would apply to all employees for each and every day worked on or in the excavation of the footing from the date of inception.

EXHIBIT D

EXHIBIT 1
GROUP 1-f: Wire winding machine in connection with guniting or shot crete
GROUP 1-g, CONTRA COSTA COUNTY: Pipelayer (including grade checking in connection with pipelaying); Caulker; Bander; Pipewrapper; Conduit layer; Plastic pipe layer; Pressure pipe tester; No joint pipe and stripping of same, including repair of voids; Precast manhole setters, cast in place manhole form setters
GROUP 2: Asphalt shoveler; Cement dumper and handling dry cement or gypsum; Choke-setter and rigger (clearing work); Concrete bucket dumper and chute; Concrete chipping and grinding; Concrete laborer (wet or dry); Driller tender, chuck tender, nipper; Guinea chaser (stake), grout crew; High pressure nozzle, adductor; Hydraulic monitor (over 100 lbs. pressure); Loading and unloading, carrying and hauling of all rods and materials for use in reinforcing concrete construction; Pittsburgh chipper and similar type brush shredders; Sloper; Single foot, hand-held, pneumatic
tamper; All pneumatic, air, gas and electric tools not
listed in Groups 1 through 1-f; Jacking of pipe - under 12 inches
GROUP 3: Construction laborers, including bridge and general laborer; Dump, load spotter; Flag person; Fire watcher; Fence erector; Guardrail erector; Gardener, horticultural and landscape laborer; Jetting; Limber, brush loader and piler; Pavement marker (button setter); Maintenance, repair track and road beds; Streetcar and railroad construction track laborer; Temporary air and water lines, Victaulic or similar; Tool room attendant (jobsite only)
GROUP 4: Final clean-up work of debris, grounds and building including but not limited to: street cleaner; cleaning and washing windows; brick cleaner (jobsite only); material cleaner (jobsite only). The classification ""material
cleaner"" is to be utilized under the following conditions:

A: at demolition site for the salvage of the material.

B: at the conclusion of a job where the material is to be salvaged and stocked to be reused on another job.

C: for the cleaning of salvage material at the jobsite or temporary jobsite yard.

The material cleaner classification should not be used in the performance of ""form stripping, cleaning and oiling and moving to the next point of erection"".
--------------------------------------------------------

GUNITE LABORER CLASSIFICATIONS
GROUP 1: Structural Nozzleman
GROUP 2: Nozzleman, Gunman, Potman, Groundman
GROUP 3: Reboundman
GROUP 4: Gunite laborer
----------------------------------------------------------

WRECKING WORK LABORER CLASSIFICATIONS
GROUP 1: Skilled wrecker (removing and salvaging of sash,

EXHIBIT D

EXHIBIT 1
windows and materials)
GROUP 2: Semi-skilled wrecker (salvaging of other building materials)
GROUP 1-g, CONTRA COSTA COUNTY: Pipelayer (including grade checking in connection with pipelaying); Caulker; Bander; Pipewrapper; Conduit layer; Plastic pipe layer; Pressure pipe tester; No joint pipe and stripping of same, including repair of voids; Precast manhole setters, cast in place manhole form setters
---------------------------------------------------------------- LABO0324-014 07/01/2023
CONTRA COSTA COUNTY:

Rates Fringes
Brick Tender.....................$ 37.05 27.45 FOOTNOTES: Work on jobs where heat-protective clothing is required: $2.00 per hour additional. Work at grinders: $.25 per hour additional. Manhole work: $2.00 per day additional. ---------------------------------------------------------------- LABO0324-018 07/01/2023
ALAMEDA AND CONTRA COSTA COUNTIES:

Rates Fringes
Plasterer tender.................$ 41.93 30.32 Work on a swing stage scaffold: $1.00 per hour additional. ---------------------------------------------------------------- LABO1130-002 07/01/2023

MARIPOSA, MERCED, STANISLAUS, AND TUOLUMNE COUNTIES
Rates Fringes

LABORER (TRAFFIC CONTROL/LANE

CLOSURE)
Escort Driver, Flag Person..$ 36.26 27.30
Traffic Control Person I....$ 36.56 27.30
Traffic Control Person II...$ 34.06 27.30
TRAFFIC CONTROL PERSON I: Layout of traffic control, crash cushions, construction area and roadside signage.

TRAFFIC CONTROL PERSON II: Installation and removal of
temporary/permanent signs, markers, delineators and crash cushions.
---------------------------------------------------------------- LABO1130-003 06/26/2023

MARIPOSA, MERCED, STANISLAUS, AND TUOLUMNE COUNTIES
Rates Fringes
Tunnel and Shaft Laborers:

GROUP 1.....................$ 45.89 27.72

EXHIBIT D

EXHIBIT 1
GROUP 2.....................$ 45.66 27.72
GROUP 3.....................$ 45.41 27.72
GROUP 4.....................$ 44.96 27.72
GROUP 5.....................$ 44.42 27.72
Shotcrete Specialist........$ 46.41 27.72

TUNNEL AND SHAFT CLASSIFICATIONS
GROUP 1: Diamond driller; Groundmen; Gunite and shotcrete nozzlemen
GROUP 2: Rodmen; Shaft work & raise (below actual or
excavated ground level)
GROUP 3: Bit grinder; Blaster, driller, powdermen, heading; Cherry pickermen - where car is lifted; Concrete finisher in tunnel; Concrete screedman; Grout pumpman and potman; Gunite & shotcrete gunman & potman; Headermen; High
pressure nozzleman; Miner - tunnel, including top and
bottom man on shaft and raise work; Nipper; Nozzleman on slick line; Sandblaster - potman, Robotic Shotcrete Placer, Segment Erector, Tunnel Muck Hauler, Steel Form raiser and setter; Timberman, retimberman (wood or steel or substitute materials therefore); Tugger (for tunnel laborer work); Cable tender; Chuck tender; Powderman - primer house
GROUP 4: Vibrator operator, pavement breaker; Bull gang - muckers, trackmen; Concrete crew - includes rodding and spreading, Dumpmen (any method)
GROUP 5: Grout crew; Reboundman; Swamper/ Brakeman
---------------------------------------------------------------- LABO1130-005 07/01/2023

MARIPOSA, MERCED, STANISLAUS AND TUOLUMNE COUNTIES
Rates Fringes

LABORER
Mason Tender-Brick..........$ 36.29 25.55
---------------------------------------------------------------- LABO1130-007 06/26/2023

MARIPOSA, MERCED, STANISLAUS, AND TUOLUMNE , COUNTIES
Rates Fringes

LABORER (CONSTRUCTION CRAFT
LABORERS - AREA B:)
Construction Specialist
Group.......................$ 36.20 27.30
GROUP 1.....................$ 35.50 27.30
GROUP 1-a...................$ 35.72 27.30
GROUP 1-c...................$ 35.55 27.30
GROUP 1-e...................$ 36.05 27.30
GROUP 1-f...................$ 36.08 27.30
GROUP 2.....................$ 35.35 27.30
GROUP 3.....................$ 35.25 27.30
GROUP 4.....................$ 28.94 27.30
See groups 1-b and 1-d under laborer classifications.

LABORER (GARDENERS,

HORTICULTURAL & LANDSCAPE
LABORERS - AREA B:)
(1) New Construction........$ 35.25 27.30

EXHIBIT D

EXHIBIT 1
(2) Establishment Warranty
Period......................$ 28.94 27.30
LABORER (GUNITE - AREA B:)
GROUP 1.....................$ 36.46 27.30
GROUP 2.....................$ 35.96 27.30
GROUP 3.....................$ 35.37 27.30
GROUP 4.....................$ 35.25 27.30
LABORER (WRECKING - AREA B:)
GROUP 1.....................$ 35.50 27.30
GROUP 2.....................$ 35.35 27.30
FOOTNOTES:

Laborers working off or with or from bos'n chairs, swinging scaffolds, belts shall receive $0.25 per hour above the applicable wage rate. This shall not apply to workers
entitled to receive the wage rate set forth in Group 1-a below.
---------------------------------------------------------

LABORER CLASSIFICATIONS
CONSTRUCTION SPECIALIST GROUP: Asphalt ironer and raker; Chainsaw; Laser beam in connection with laborers' work; Cast-in- place manhole form setter; Pressure pipelayer; Davis trencher - 300 or similar type (and all small
trenchers); Blaster; Diamond driller; Multiple unit drill; Hydraulic drill
GROUP 1: Asphalt spreader boxes (all types); Barko, Wacker and similar type tampers; Buggymobile; Caulker, bander, pipewrapper, conduit layer, plastic pipelayer; Certified hazardous waste worker including Leade Abatement;
Compactors of all types; Concrete and magnesite mixer, 1/2 yd. and under; Concrete pan work; Concrete sander; Concrete saw; Cribber and/or shoring; Cut granite curb setter;
Dri-pak-it machine; Faller, logloader and bucker; Form
raiser, slip forms; Green cutter; Headerboard, Hubsetter, aligner, by any method; High pressure blow pipe (1-1/2"" or over, 100 lbs. pressure/over); Hydro seeder and similar type; Jackhammer operator; Jacking of pipe over 12 inches; Jackson and similar type compactor; Kettle tender, pot and worker applying asphalt, lay-kold, creosote, lime, caustic and similar type materials (applying means applying,
dipping or handling of such materials); Lagging, sheeting, whaling, bracing, trenchjacking, lagging hammer; Magnesite, epoxyresin, fiberglass, mastic worker (wet or dry); No
joint pipe and stripping of same, including repair of
voids; Pavement breaker and spader, including tool grinder; Perma curb; Pipelayer (including grade checking in
connection with pipelaying); Precast-manhole setter;
Pressure pipe tester; Post hole digger, air, gas and
electric; Power broom sweeper; Power tampers of all types (except as shown in Group 2); Ram set gun and stud gun; Riprap stonepaver and rock-slinger, including placing of sacked concrete and/or sand (wet or dry) and gabions and similar type; Rotary scarifier or multiple head concrete chipping scarifier; Roto and Ditch Witch; Rototiller;
Sandblaster, pot, gun, nozzle operators; Signalling and rigging; Tank cleaner; Tree climber; Turbo blaster;
Vibrascreed, bull float in connection with laborers' work; Vibrator; Hazardous waste worker (lead removal); Asbestos and mold removal worker

EXHIBIT D

EXHIBIT 1
GROUP 1-a: Joy drill model TWM-2A; Gardner-Denver model DH143 and similar type drills; Track driller; Jack leg driller; Wagon driller; Mechanical drillers, all types regardless of type or method of power; Mechanical pipe layers, all types regardless of type or method of power; Blaster and powder; All work of loading, placing and blasting of all powder and explosives of whatever type regardless of method used for such loading and placing; High scalers (including drilling of same); Tree topper; Bit grinder
GROUP 1-b: Sewer cleaners shall receive $4.00 per day above Group 1 wage rates. ""Sewer cleaner"" means any worker who handles or comes in contact with raw sewage in small
diameter sewers. Those who work inside recently active, large diameter sewers, and all recently active sewer
manholes shal receive $5.00 per day above Group 1 wage
rates.

GROUP 1-c: Burning and welding in connection with laborers' work; Synthetic thermoplastics and similar type welding GROUP 1-d: Maintenance and repair track and road beds. All employees performing work covered herein shall receive $ .25 per hour above their regular rate for all work
performed on underground structures not specifically
covered herein. This paragraph shall not be construed to apply to work below ground level in open cut. It shall apply to cut and cover work of subway construction after the temporary cover has been placed.

GROUP 1-e: Work on and/or in bell hole footings and shafts thereof, and work on and in deep footings. (A deep footing is a hole 15 feet or more in depth.) In the event the
depth of the footing is unknown at the commencement of
excavation, and the final depth exceeds 15 feet, the deep footing wage rate would apply to all employees for each and every day worked on or in the excavation of the footing from the date of inception.

GROUP 1-f: Wire winding machine in connection with guniting or shot crete
GROUP 2: Asphalt shoveler; Cement dumper and handling dry cement or gypsum; Choke-setter and rigger (clearing work); Concrete bucket dumper and chute; Concrete chipping and grinding; Concrete laborer (wet or dry); Driller tender, chuck tender, nipper; Guinea chaser (stake), grout crew; High pressure nozzle, adductor; Hydraulic monitor (over 100 lbs. pressure); Loading and unloading, carrying and hauling of all rods and materials for use in reinforcing concrete construction; Pittsburgh chipper and similar type brush shredders; Sloper; Single foot, hand-held, pneumatic
tamper; All pneumatic, air, gas and electric tools not
listed in Groups 1 through 1-f; Jacking of pipe - under 12 inches
GROUP 3: Construction laborers, including bridge and general laborer; Dump, load spotter; Flag person; Fire watcher; Fence erector; Guardrail erector; Gardener, horticultural and landscape laborer; Jetting; Limber, brush loader and piler; Pavement marker (button setter); Maintenance, repair track and road beds; Streetcar and railroad construction track laborer; Temporary air and water lines, Victaulic or similar; Tool room attendant (jobsite only)

EXHIBIT D

EXHIBIT 1
GROUP 4: Final clean-up work of debris, grounds and building including but not limited to: street cleaner; cleaning and washing windows; brick cleaner (jobsite only); material cleaner (jobsite only). The classification ""material
cleaner"" is to be utilized under the following conditions:

A: at demolition site for the salvage of the material.

B: at the conclusion of a job where the material is to be salvaged and stocked to be reused on another job.

C: for the cleaning of salvage material at the jobsite or temporary jobsite yard.

The material cleaner classification should not be used in the performance of ""form stripping, cleaning and oiling and moving to the next point of erection"".
--------------------------------------------------------

GUNITE LABORER CLASSIFICATIONS
GROUP 1: Structural Nozzleman
GROUP 2: Nozzleman, Gunman, Potman, Groundman
GROUP 3: Reboundman
GROUP 4: Gunite laborer
----------------------------------------------------------

WRECKING WORK LABORER CLASSIFICATIONS
GROUP 1: Skilled wrecker (removing and salvaging of sash, windows and materials)
GROUP 2: Semi-skilled wrecker (salvaging of other building materials)
---------------------------------------------------------------- LABO1130-008 07/01/2023

CALAVERAS, FRESNO, KINGS, MADERA, MARIPOSA, MERCED, SAN

JOAQUIN, STANISLAUS & TUOLUMNE
Rates Fringes
Plasterer tender.................$ 39.77 28.54 Work on a swing stage scaffold: $1.00 per hour additional. ---------------------------------------------------------------- LABO1130-009 07/01/2023

MARIPOSA, MERCED, STANISLAUS, AND TUOLUMNE COUNTIES
Rates Fringes
LABORER (Plaster Tender).........$ 39.77 28.54 Work on a swing stage scaffold: $1.00 per hour additional. ---------------------------------------------------------------- PAIN0016-001 01/01/2025

ALAMEDA, CONTRA COSTA, MONTEREY, SAN BENITO, SAN MATEO, SANTA

CLARA, AND SANTA CRUZ COUNTIES

EXHIBIT D

EXHIBIT 1
Rates Fringes
Painters:........................$ 53.38 28.04 PREMIUMS:

EXOTIC MATERIALS - $1.25 additional per hour.

SPRAY WORK: - $0.50 additional per hour.

INDUSTRIAL PAINTING - $0.25 additional per hour
[Work on industrial buildings used for the manufacture and processing of goods for sale or service; steel construction (bridges), stacks, towers, tanks, and similar structures] HIGH WORK:
over 50 feet - $2.00 per hour additional
100 to 180 feet - $4.00 per hour additional
Over 180 feet - $6.00 per houir additional
---------------------------------------------------------------- PAIN0016-003 01/01/2025
AREA 1: ALAMEDA, CONTRA COSTA, SAN FRANCISCO, SAN MATEO & SANTA

CLARA COUNTIES
AREA 2: CALAVERAS, MARIPOA, MERCED, MONTEREY, SAN BENITO, SAN

JOAQUIN, SANTA CRUZ, STANISLAUS & TUOLUMNE COUNTIES
Rates Fringes
Drywall Finisher/Taper
AREA 1......................$ 63.76 32.69
AREA 2......................$ 59.63 31.29
---------------------------------------------------------------- PAIN0016-012 01/01/2024

ALAMEDA, CONTRA COSTA, MARIPOSA, MERCED, MONTEREY, SAN BENITO,

SAN FRANCISCO, SAN MATEO, SANTA CLARA AND SANTA CRUZ COUNTIES Rates Fringes
SOFT FLOOR LAYER.................$ 59.00 33.03 ---------------------------------------------------------------- PAIN0016-015 01/01/2025

CALAVERAS, MARIPOSA, MERCED, SAN JOAQUIN, STANISLAUS & TUOLUMNE

COUNTIES
Rates Fringes

PAINTER
Brush.......................$ 43.45 22.80
FOOTNOTES:

SPRAY/SANDBLAST: $0.50 additional per hour.

EXOTIC MATERIALS: $1.25 additional per hour.

HIGH TIME: Over 50 ft above ground or water level $2.00 additional per hour. 100 to 180 ft above ground or water level $4.00 additional per hour. Over 180 ft above ground or water level $6.00 additional per hour.
----------------------------------------------------------------

EXHIBIT D

EXHIBIT 1
PAIN0016-022 01/01/2025

SAN FRANCISCO COUNTY
Rates Fringes
PAINTER..........................$ 57.00 28.04 ---------------------------------------------------------------- PAIN0169-001 01/01/2023
FRESNO, KINGS, MADERA, MARIPOSA AND MERCED COUNTIES:

Rates Fringes
GLAZIER..........................$ 44.33 28.88 ---------------------------------------------------------------- PAIN0169-005 01/01/2024

ALAMEDA CONTRA COSTA, MONTEREY, SAN BENITO, SAN FRANCISCO, SAN

MATEO, SANTA CLARA & SANTA CRUZ COUNTIES
Rates Fringes
GLAZIER..........................$ 56.22 34.00 ---------------------------------------------------------------- PAIN0294-004 07/01/2023

FRESNO, KINGS AND MADERA COUNTIES
Rates Fringes

PAINTER
Brush, Roller...............$ 34.49 21.80
Drywall Finisher/Taper......$ 35.74 21.80
FOOTNOTE:

Spray Painters & Paperhangers recive $1.00 additional per hour. Painters doing Drywall Patching receive $1.25
additional per hour. Lead Abaters & Sandblasters receive $1.50 additional per hour. High Time - over 30 feet (does not include work from a lift) $0.75 per hour additional. ---------------------------------------------------------------- PAIN0294-005 01/01/2023

FRESNO, KINGS & MADERA
Rates Fringes
SOFT FLOOR LAYER.................$ 38.53 23.19 ---------------------------------------------------------------- PAIN0767-001 01/01/2024
CALAVERAS, SAN JOAQUIN, STANISLAUS AND TUOLUMNE COUNTIES:

Rates Fringes
GLAZIER..........................$ 43.25 35.62 PAID HOLIDAYS: New Year's Day, Martin Luther King, Jr. Day, President's Day, Memorial Day, Independence Day, Labor Day, Veteran's Day, Thanksgiving Day, and Christmas Day.

Employee required to wear a body harness shall receive $1.50

EXHIBIT D

EXHIBIT 1
per hour above the basic hourly rate at any elevation.
---------------------------------------------------------------- PAIN1176-001 07/01/2022
HIGHWAY IMPR0VEMENT
Rates Fringes
Parking Lot Striping/Highway
Marking:

GROUP 1.....................$ 40.83 17.62
GROUP 2.....................$ 34.71 17.62
GROUP 3.....................$ 35.11 17.62

CLASSIFICATIONS
GROUP 1: Striper: Layout and application of painted traffic stripes and marking; hot thermo plastic; tape, traffic
stripes and markings
GROUP 2: Gamecourt & Playground Installer
GROUP 3: Protective Coating, Pavement Sealing
---------------------------------------------------------------- PAIN1237-003 01/01/2024
CALAVERAS; SAN JOAQUIN COUNTIES; STANISLAUS AND TUOLUMNE COUNTIES:

Rates Fringes
SOFT FLOOR LAYER.................$ 48.54 26.59 ---------------------------------------------------------------- PLAS0066-002 07/01/2019
ALAMEDA, CONTRA COSTA, SAN MATEO AND SAN FRANCISCO COUNTIES:

Rates Fringes
PLASTERER........................$ 42.41 30.73 ---------------------------------------------------------------- PLAS0300-001 07/01/2018
Rates Fringes

PLASTERER
AREA 188: Fresno...........$ 32.70 31.68
AREA 224: San Benito,
Santa Clara, Santa Cruz.....$ 32.88 31.68
AREA 295: Calaveras & San
Joaquin Couonties...........$ 32.70 31.68
AREA 337: Monterey County..$ 32.88 31.68
AREA 429: Mariposa,
Merced, Stanislaus,
Tuolumne Counties...........$ 32.70 31.68
---------------------------------------------------------------- PLAS0300-005 07/01/2016
Rates Fringes
CEMENT MASON/CONCRETE FINISHER...$ 32.15 23.27 ----------------------------------------------------------------

EXHIBIT D

EXHIBIT 1
PLUM0038-001 07/01/2023

SAN FRANCISCO COUNTY
Rates Fringes
PLUMBER (Plumber,
Steamfitter, Refrigeration
Fitter)..........................$ 85.50 48.98 ---------------------------------------------------------------- * PLUM0038-005 07/01/2025

SAN FRANCISCO COUNTY
Rates Fringes
Landscape/Irrigation Fitter
(Underground/Utility Fitter).....$ 77.35 36.53 ---------------------------------------------------------------- PLUM0062-001 07/01/2025

MONTEREY AND SANTA CRUZ COUNTIES
Rates Fringes
PLUMBER & STEAMFITTER............$ 55.85 42.85 ---------------------------------------------------------------- PLUM0159-001 07/01/2025

CONTRA COSTA COUNTY
Rates Fringes
Plumber and steamfitter
(1) Refrigeration...........$ 67.68 49.04
(2) All other work..........$ 68.57 49.04
---------------------------------------------------------------- PLUM0246-001 01/01/2025

FRESNO, KINGS & MADERA COUNTIES
Rates Fringes
PLUMBER & STEAMFITTER............$ 51.65 41.59 ---------------------------------------------------------------- * PLUM0246-004 01/01/2017

FRESNO, MERCED & SAN JOAQUIN COUNIES
Rates Fringes
PLUMBER (PIPE TRADESMAN).........$ 13.00 ** 10.74 PIPE TRADESMAN SCOPE OF WORK:

Installation of corrugated metal piping for drainage, as well as installation of corrugated metal piping for culverts in connection with storm sewers and drains; Grouting, dry
packing and diapering of joints, holes or chases including paving over joints, in piping; Temporary piping for dirt work for building site preparation; Operating jack hammers, pavement breakers, chipping guns, concrete saws and spades to cut holes, chases and channels for piping systems;
Digging, grading, backfilling and ground preparation for all types of pipe to all points of the jobsite; Ground
preparation including ground leveling, layout and planting

EXHIBIT D

EXHIBIT 1
of shrubbery, trees and ground cover, including watering, mowing, edging, pruning and fertilizing, the breaking of concrete, digging, backfilling and tamping for the
preparation and completion of all work in connection with lawn sprinkler and landscaping; Loading, unloading and
distributing materials at jobsite; Putting away materials in storage bins in jobsite secure storage area; Demolition of piping and fixtures for remodeling and additions;
Setting up and tearing down work benches, ladders and job shacks; Clean-up and sweeping of jobsite; Pipe wrapping and waterproofing where tar or similar material is applied for protection of buried piping; Flagman
---------------------------------------------------------------- PLUM0342-001 07/01/2025

ALAMEDA & CONTRA COSTA COUNTIES
Rates Fringes

PIPEFITTER
CONTRA COSTA COUNTY.........$ 80.50 50.45

PLUMBER, PIPEFITTER,

STEAMFITTER
ALAMEDA COUNTY..............$ 80.50 50.45
---------------------------------------------------------------- PLUM0355-004 07/01/2024

ALAMEDA, CALAVERAS, CONTRA COSTA, FRESNO, KINGS, MADERA,

MARIPOSA, MERCED, MONTEREY, SAN BENITO, SAN JOAQUIN, SAN MATEO, SANTA CLARA, SANTA CRUZ, STANISLAUS, AND TUOLUMNE COUNTIES:

Rates Fringes
Underground Utility Worker
/Landscape Fitter...........$ 34.51 18.30
---------------------------------------------------------------- PLUM0393-001 07/01/2021

SAN BENITO AND SANTA CLARA COUNTIES
Rates Fringes
PLUMBER/PIPEFITTER...............$ 68.76 46.63 ---------------------------------------------------------------- PLUM0442-001 07/01/2025

CALAVERAS, MARIPOSA, MERCED, SAN JOAQUIN, STANISLAUS & TUOLUMNE

COUNTIES
Rates Fringes
PLUMBER & STEAMFITTER............$ 56.60 38.14 ---------------------------------------------------------------- PLUM0467-001 07/01/2025

SAN MATEO COUNTY
Rates Fringes
Plumber/Pipefitter/Steamfitter...$ 87.75 41.44 ---------------------------------------------------------------- ROOF0027-002 09/01/2024

EXHIBIT D

EXHIBIT 1

FRESNO, KINGS, AND MADERA COUNTIES
Rates Fringes
ROOFER...........................$ 45.76 16.86 FOOTNOTE: Work with pitch, pitch base of pitch impregnated products or any material containing coal tar pitch, on any building old or new, where both asphalt and pitchers are used in the application of a built-up roof or tear off:
$2.00 per hour additional.
---------------------------------------------------------------- ROOF0040-002 08/01/2024
SAN FRANCISCO & SAN MATEO COUNTIES:

Rates Fringes
ROOFER...........................$ 55.30 22.97 ---------------------------------------------------------------- ROOF0081-001 08/01/2024
ALAMEDA AND CONTRA COSTA COUNTIES:

Rates Fringes
Roofer...........................$ 54.94 23.34 ---------------------------------------------------------------- ROOF0081-004 08/01/2024

CALAVERAS, MARIPOSA, MERCED, SAN JOAQUIN, STANISLAUS AND TUOLUMNE COUNTIES:

Rates Fringes
ROOFER...........................$ 49.65 22.19 ---------------------------------------------------------------- ROOF0095-002 08/01/2023
MONTEREY, SAN BENITO, SANTA CLARA, AND SANTA CRUZ COUNTIES:

Rates Fringes
ROOFER
Bitumastic, Enameler, Coal
Tar, Pitch and Mastic
worker......................$ 57.17 21.51
Journeyman..................$ 53.17 21.51
Kettle person (2 kettles)...$ 55.17 21.51
---------------------------------------------------------------- * SFCA0483-001 08/04/2025

ALAMEDA, CONTRA COSTA, SAN FRANCISCO, SAN MATEO AND SANTA CLARA COUNTIES:

Rates Fringes
SPRINKLER FITTER (FIRE)..........$ 82.44 40.10 ---------------------------------------------------------------- SFCA0669-011 04/01/2025

EXHIBIT D

EXHIBIT 1

CALAVERAS, FRESNO, KINGS, MADERA, MARIPOSA, MERCED, MONTEREY,

SAN BENITO, SAN JOAQUIN, SANTA CRUZ, STANISLAUS AND TUOLUMNE COUNTIES:

Rates Fringes
SPRINKLER FITTER.................$ 49.69 28.42 ---------------------------------------------------------------- SHEE0104-001 07/01/2020
AREA 1: ALAMEDA, CONTRA COSTA, SAN FRANCISCO, SAN MATEO, SANTA CLARA
AREA 2: MONTEREY & SAN BENITO
AREA 3: SANTA CRUZ
Rates Fringes

SHEET METAL WORKER
AREA 1:

Mechanical Contracts
under $200,000.............$ 55.92 45.29
All Other Work.............$ 64.06 46.83
AREA 2......................$ 52.90 36.44
AREA 3......................$ 55.16 34.18
---------------------------------------------------------------- SHEE0104-003 07/01/2021
CALAVERAS AND SAN JOAQUIN COUNTIES:

Rates Fringes
SHEET METAL WORKER...............$ 44.34 39.22 ---------------------------------------------------------------- SHEE0104-005 07/01/2021
MARIPOSA, MERCED, STANISLAUS AND TUOLUMNE COUNTIES:

Rates Fringes
SHEET METAL WORKER (Excluding
metal deck and siding)...........$ 41.28 45.41 ---------------------------------------------------------------- SHEE0104-007 07/01/2021
FRESNO, KINGS, AND MADERA COUNTIES:

Rates Fringes
SHEET METAL WORKER...............$ 44.07 40.79 ---------------------------------------------------------------- SHEE0104-015 07/01/2020

ALAMEDA, CONTRA COSTA, MONTEREY, SAN BENITO, SAN FRANCISCO, SAN MATEO, SANTA CLARA AND SANTA CRUZ COUNTIES:

Rates Fringes
SHEET METAL WORKER (Metal
Decking and Siding only).........$ 44.45 35.55 ----------------------------------------------------------------

EXHIBIT D

EXHIBIT 1
SHEE0104-018 07/01/2020

CALAVERAS, FRESNO, KINGS, MADERA, MARIPOSA, MERCED, SAN JOAQUIN, STANISLAUS AND TUOLUMNE COUNTIES:

Rates Fringes
Sheet metal worker (Metal
decking and siding only).........$ 44.45 35.55 ---------------------------------------------------------------- TEAM0094-001 07/01/2025
Rates Fringes
Truck drivers:

GROUP 1.....................$ 43.26 34.28
GROUP 2.....................$ 43.56 34.28
GROUP 3.....................$ 43.86 34.28
GROUP 4.....................$ 44.21 34.28
GROUP 5.....................$ 44.56 34.28
FOOTNOTES:

Articulated dump truck; Bulk cement spreader (with or without auger); Dumpcrete truck; Skid truck (debris box); Dry
pre-batch concrete mix trucks; Dumpster or similar type; Slurry truck: Use dump truck yardage rate.

Heater planer; Asphalt burner; Scarifier burner; Industrial lift truck (mechanical tailgate); Utility and clean-up
truck: Use appropriate rate for the power unit or the
equipment utilized.

TRUCK DRIVER CLASSIFICATIONS
GROUP 1: Dump trucks, under 6 yds.; Single unit flat rack (2- axle unit); Nipper truck (when flat rack truck is used
appropriate flat rack shall apply); Concrete pump truck (when flat rack truck is used appropriate flat rack shall apply); Concrete pump machine; Fork lift and lift jitneys; Fuel and/or grease truck driver or fuel person; Snow buggy; Steam cleaning; Bus or personhaul driver; Escort or pilot car driver; Pickup truck; Teamster oiler/greaser and/or serviceperson; Hook tender (including loading and
unloading); Team driver; Tool room attendant (refineries) GROUP 2: Dump trucks, 6 yds. and under 8 yds.; Transit
mixers, through 10 yds.; Water trucks, under 7,000 gals.; Jetting trucks, under 7,000 gals.; Single-unit flat rack (3-axle unit); Highbed heavy duty transport; Scissor truck; Rubber-tired muck car (not self-loaded); Rubber-tired truck jumbo; Winch truck and ""A"" frame drivers; Combination winch truck with hoist; Road oil truck or bootperson;
Buggymobile; Ross, Hyster and similar straddle carriers; Small rubber-tired tractor
GROUP 3: Dump trucks, 8 yds. and including 24 yds.; Transit mixers, over 10 yds.; Water trucks, 7,000 gals. and over; Jetting trucks, 7,000 gals. and over; Vacuum trucks under 7500 gals. Trucks towing tilt bed or flat bed pull
trailers; Lowbed heavy duty transport; Heavy duty transport tiller person; Self- propelled street sweeper with
self-contained refuse bin; Boom truck - hydro-lift or
Swedish type extension or retracting crane; P.B. or similar type self-loading truck; Tire repairperson; Combination

EXHIBIT D

EXHIBIT 1
bootperson and road oiler; Dry distribution truck (A
bootperson when employed on such equipment, shall receive the rate specified for the classification of road oil
trucks or bootperson); Ammonia nitrate distributor, driver and mixer; Snow Go and/or plow
GROUP 4: Dump trucks, over 25 yds. and under 65 yds.; Water pulls - DW 10's, 20's, 21's and other similar equipment when pulling Aqua/pak or water tank trailers; Helicopter pilots (when transporting men and materials); Lowbedk Heavy Duty Transport up to including 7 axles; DW10's, 20's, 21's and other similar Cat type, Terra Cobra, LeTourneau Pulls, Tournorocker, Euclid and similar type equipment when
pulling fuel and/or grease tank trailers or other
miscellaneous trailers; Vacuum Trucks 7500 gals and over and truck repairman
GROUP 5: Dump trucks, 65 yds. and over; Holland hauler; Low bed Heavy Duty Transport over 7 axles
---------------------------------------------------------------- WELDERS - Receive rate prescribed for craft performing
operation to which welding is incidental.
================================================================ ** Workers in this classification may be entitled to a higher minimum wage under Executive Order 14026 ($17.75) or 13658 ($13.30). Please see the Note at the top of the wage
determination for more information. Please also note that the minimum wage requirements of Executive Order 14026 are not currently being enforced as to any contract or subcontract to which the states of Texas, Louisiana, or Mississippi, including their agencies, are a party.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at
https://www.dol.gov/agencies/whd/government-contracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (iii)).
---------------------------------------------------------------- The body of each wage determination lists the classifications and wage rates that have been found to be prevailing for the

EXHIBIT D

EXHIBIT 1
type(s) of construction and geographic area covered by the wage determination. The classifications are listed in alphabetical order under rate identifiers indicating whether the particular rate is a union rate (current union negotiated rate), a survey rate, a weighted union average rate, a state adopted rate, or a supplemental classification rate.

Union Rate Identifiers
A four-letter identifier beginning with characters other than ""SU"", ""UAVG"", ?SA?, or ?SC? denotes that a union rate was prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2024. PLUM is an identifier of the union whose collectively bargained rate prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. The date, 07/01/2024 in the example, is the effective date of the most current negotiated rate.

Union prevailing wage rates are updated to reflect all changes over time that are reported to WHD in the rates
in the collective bargaining agreement (CBA) governing the classification.

Union Average Rate Identifiers
The UAVG identifier indicates that no single rate prevailed for those classifications, but that 100% of the data reported for the classifications reflected union rates. EXAMPLE:

UAVG-OH-0010 01/01/2024. UAVG indicates that the rate is a weighted union average rate. OH indicates the State of Ohio.

The next number, 0010 in the example, is an internal number used in producing the wage determination. The date, 01/01/2024 in the example, indicates the date the wage determination was updated to reflect the most current union average rate.

A UAVG rate will be updated once a year, usually in January, to reflect a weighted average of the current rates in the
collective bargaining agreements on which the rate is based.

Survey Rate Identifiers
The ""SU"" identifier indicates that either a single non-union rate prevailed (as defined in 29 CFR 1.2) for this
classification in the survey or that the rate was derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As a weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SUFL2022-007 6/27/2024. SU indicates the rate is a single non-union
prevailing rate or a weighted average of survey data for that classification. FL indicates the State of Florida. 2022 is the year of the survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. The date, 6/27/2024 in the example, indicates the survey completion date for the classifications and rates under that identifier. ?SU? wage rates typically remain in effect until a new survey is conducted. However, the Wage and Hour Division (WHD) has the discretion to update such rates under 29 CFR 1.6(c)(1).

EXHIBIT D

EXHIBIT 1
State Adopted Rate Identifiers
The ""SA"" identifier indicates that the classifications and prevailing wage rates set by a state (or local) government were adopted under 29 C.F.R 1.3(g)-(h). Example: SAME2023-007 01/03/2024. SA reflects that the rates are state adopted. ME refers to the State of Maine. 2023 is the year during which the state completed the survey on which the listed classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination.

The date, 01/03/2024 in the example, reflects the date on which the classifications and rates under the ?SA? identifier took effect under state law in the state from which the rates were adopted.
-----------------------------------------------------------

WAGE DETERMINATION APPEALS PROCESS
1) Has there been an initial decision in the matter? This can be:
a) a survey underlying a wage determination
b) an existing published wage determination
c) an initial WHD letter setting forth a position on
a wage determination matter
d) an initial conformance (additional classification
and rate) determination
On survey related matters, initial contact, including requests for summaries of surveys, should be directed to the WHD Branch of Wage Surveys. Requests can be submitted via email to [email protected] or by mail to:

Branch of Wage Surveys
Wage and Hour Division
U.S. Department of Labor
200 Constitution Avenue, N.W.

Washington, DC 20210
Regarding any other wage determination matter such as
conformance decisions, requests for initial decisions should be directed to the WHD Branch of Construction Wage Determinations.

Requests can be submitted via email to [email protected] or by mail to:

Branch of Construction Wage Determinations
Wage and Hour Division
U.S. Department of Labor
200 Constitution Avenue, N.W.

Washington, DC 20210
2) If an initial decision has been issued, then any interested party (those affected by the action) that disagrees with the decision can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7).

Requests for review and reconsideration can be submitted via email to [email protected] or by mail to:

Wage and Hour Administrator
U.S. Department of Labor
200 Constitution Avenue, N.W.

Washington, DC 20210
The request should be accompanied by a full statement of the

EXHIBIT D

EXHIBIT 1
interested party's position and any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.
3) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board
U.S. Department of Labor
200 Constitution Avenue, N.W.

Washington, DC 20210.
================================================================ END OF GENERAL DECISION"

EXHIBIT D

EXHIBIT 1
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language

October 2023
EXHIBI
T 12-G: REQUIRED FEDERAL-AID CONTRACT LANGUAGE
(For Local Assistance Construction Projects)
The fo
llowing language must be incorporated into all Local Assistance Federal-aid construction contracts.

The following language, with minor edits, was taken from the Code of Federal Regulations.

MAINTAIN RECORDS AND SUBMIT REPORTS DOCUMENTING YOUR PERFORMANCE UNDER THIS

SECTION

1. BID OPENING ....................................................................................................................................................... 2

2. BID RIGGING ........................................................................................................................................................ 2

3. CONTRACT AWARD ............................................................................................................................................ 2

4. CONTRACTOR LICENSE .................................................................................................................................... 2

5. CHANGED CONDITIONS ..................................................................................................................................... 2 A. Differing Site Conditions ....................................................................................................................... 2 B. Suspensions of Work Ordered by the Engineer .................................................................................. 2 C. Significant Changes in the Character of Work .................................................................................. 3

6. BEGINNING OF WORK, TIME OF COMPLETION AND LIQUIDATED DAMAGES ......................................... 3

7. BUY AMERICA ................................................................................................................................................... 3

8. QUALITY ASSURANCE ..................................................................................................................................... 4

9. PROMPT PAYMENT .......................................................................................................................................... 5

10. FORM FHWA-1273 REQUIRED CONTRACT PROVISIONS FEDERAL-AID CONTRACTS ............................ 5

11. TITLE VI ASSURANCES .................................................................................................................................... 5

12. FEDERAL TRAINEE PROGRAM ....................................................................................................................... 10

13. PROHIBITION OF CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE EQUIPMENT AND SERVIC
ES .......................................................................................................................................................... 11

EXHIBIT E

EXHIBIT 1
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language

October 2023

1. BID OPENING
The Agency publicly opens and reads bids at the time and place shown on the Notice to Contractors.

2. BID RIGGING
The U.S. Department of Transportation (DOT) provides a toll-free hotline to report bid rigging activities. Use the hotline to report bid rigging, bidder collusion, and other fraudulent activities. The hotline number is (800) 424- 9071. The service is available 24 hours 7 days a week and is confidential and anonymous. The hotline is part of the DOT's effort to identify and investigate highway construction contract fraud and abuse and is operated under the direction of the DOT Inspector General.

3. CONTRACT AWARD
If the Agency awards the contract, the award is made to the lowest responsible and responsive bidder.

4. CONTRACTOR LICENSE
The Contractor must be properly licensed as a contractor from contract award through Contract acceptance (23 CFR 635.110).

5. CHANGED CONDITIONS
A. Differing Site Conditions

1. During the progress of the work, if subsurface or latent physical conditions are encountered at the site differing materially from those indicated in the contract or if unknown physical conditions of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent in the work provided for in the contract, are encountered at the site, the party discovering such conditions shall promptly notify the other party in writing of the specific differing conditions before the site is disturbed and before the affected work is performed.

2. Upon written notification, the engineer will investigate the conditions, and if it is determined that the conditions materially differ and cause an increase or decrease in the cost or time required for the performance of any work under the contract, an adjustment, excluding anticipated profits, will be made and the contract modified in writing accordingly. The engineer will notify the contractor of the determination whether or not an adjustment of the contract is warranted.

3. No contract adjustment which results in a benefit to the contractor will be allowed unless the contractor has provided the required written notice.

4. No contract adjustment will be allowed under this clause for any effects caused on unchanged work. [This provision may be omitted by the Local Agency, at their option.]

B. Suspensions of Work Ordered by the Engineer

1. If the performance of all or any portion of the work is suspended or delayed by the engineer in writing for an unreasonable period of time (not originally anticipated, customary, or inherent to the construction industry) and the contractor believes that additional compensation and/or contract time is due as a result of such suspension or delay, the contractor shall submit to the engineer in writing a request for adjustment within 7 calendar days of receipt of the notice to resume work. The request shall set forth the reasons and support for such adjustment.

2. Upon receipt, the engineer will evaluate the contractor's request. If the engineer agrees that the cost and/or time required for the performance of the contract has increased as a result of such suspension and the suspension was caused by conditions beyond the control of and not the fault of the contractor, its suppliers, or subcontractors at any approved tier, and not caused by weather, the engineer will make an adjustment (excluding profit) and modify the contract in writing accordingly. The contractor will be notified of the engineer's determination whether or not an adjustment of the contract is warranted.

EXHIBIT E

EXHIBIT 1
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language

October 2023

3. No contract adjustment will be allowed unless the contractor has submitted the request for adjustment within the time prescribed.

4. No contract adjustment will be allowed under this clause to the extent that performance would have been suspended or delayed by any other cause, or for which an adjustment is provided or excluded under any other term or condition of this contract.

C. Significant Changes in the Character of Work

1. The engineer reserves the right to make, in writing, at any time during the work, such changes in quantities and such alterations in the work as are necessary to satisfactorily complete the project. Such changes in quantities and alterations shall not invalidate the contract nor release the surety, and the contractor agrees to perform the work as altered.

2. If the alterations or changes in quantities significantly change the character of the work under the contract, whether such alterations or changes are in themselves significant changes to the character of the work or by affecting other work cause such other work to become significantly different in character, an adjustment, excluding anticipated profit, will be made to the contract. The basis for the adjustment shall be agreed upon prior to the performance of the work. If a basis cannot be agreed upon, then an adjustment will be made either for or against the contractor in such amount as the engineer may determine to be fair and equitable.

3. If the alterations or changes in quantities do not significantly change the character of the work to be performed under the contract, the altered work will be paid for as provided elsewhere in the contract.

4. The term “significant change” shall be construed to apply only to the following circumstances:
• When the character of the work as altered differs materially in kind or nature from that involved or included in the original proposed construction; or
• When a major item of work, as defined elsewhere in the contract, is increased in excess of 125 percent or decreased below 75 percent of the original contract quantity. Any allowance for an increase in quantity shall apply only to that portion in excess of 125 percent of original contract item quantity, or in case of a decrease below 75 percent, to the actual amount of work performed.

6. BEGINNING OF WORK, TIME OF COMPLETION AND LIQUIDATED DAMAGES The Contractor shall begin work within 15 calendar days after the issuance of the Notice to Proceed.

This work shall be diligently prosecuted to completion before the expiration of WORKI NG DAYS beginning on the fifteenth calendar day after the date shown on the Notice to Proceed.

The Contractor shall pay to the City/County the sum of $ per day, for each and every calendar days’ delay in finishing the work in excess of the number of working days prescribed above.

7. BUY AMERICA
Buy America Requirements apply to steel and iron, manufactured products, and construction materials permanently incorporated into the project.

Steel and Iron Materials
All steel and iron materials must be melted and manufactured in the United States except:

1. Foreign pig iron and processed, pelletized, and reduced iron ore may be used in the domestic production of the steel and iron materials [60 Fed Reg 15478 (03/24/1995)];

2. If the total combined cost of the materials produced outside the United States does not exceed the greater of 0.1 percent of the total contract amount or $2,500, materials produced outside the United States may be used if authorized.

Furnish steel and iron materials to be incorporated into the work with certificates of compliance and certified mill test reports. Mill test reports must indicate where the steel and iron were melted and manufactured. All melting and manufacturing processes for these materials, including an application of a coating, must occur in the United States. Coating includes all processes that protect or enhance the value of the material to which the coating is applied.

EXHIBIT E

EXHIBIT 1
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language

October 2023

Manufactured Products
Iron and steel used in precast concrete manufactured products must meet the requirements of the above section (Steel and Iron Materials) regardless of the amount used. Iron and steel used in other manufactured products must meet the requirements of the above section (Steel and Iron Materials) if the weight of steel and iron components constitute 90 percent or more of the total weight of the manufactured product.

Construction Materials
Buy America requirements apply to the following construction materials that are or consist primarily of:

1. Non-ferrous metals

2. Plastic and polymer-based products such as:

2.1 Polyvinylchloride

2.2 Composite Building Materials

3. Glass

4. Fiber optic cable (including drop cable)

5. Optical fiber

6. Lumber

7. Engineered wood

8. Drywall

All manufacturing processes for these materials as defined in 2 CFR 184.6 must occur in the United States.

Where one or more of these construction materials have been combined by a manufacturer with other materials through a manufacturing process, Buy America requirements do not apply unless otherwise specified.

Furnish construction materials to be incorporated into the work with certificates of compliance with each project delivery. Manufacturer’s certificate of compliance must identify where the construction material was manufactured and attest specifically to Buy America compliance.

All manufacturing processes for these materials must occur in the United States.

Buy America requirements do not apply to the following:

1. Tools and construction equipment used in performing the work

2. Temporary work that is not incorporated into the finished project

Waivers
If Buy America waivers are granted, use the following language to include in the contract:

The following steel and iron products, manufactured products, or construction materials have received an approve
d Buy America waiver for this contract, and therefore, are not subject to Buy America requirements:

1. 2.

8. QUALITY ASSURANCE
The Local Agency uses a Quality Assurance Program (QAP) to ensure a material is produced to comply with the Contract. The Local Agency may examine the records and reports of tests the prime contractor performs if they are available at the job site. Schedule work to allow time for QAP.

EXHIBIT E

EXHIBIT 1
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language

October 2023

9. PROMPT PAYMENT
A. FROM THE AGENCY TO THE CONTRACTORS

The Local Agency shall make all project progress payment within 30 days after receipt of an undisputed and properly submitted payment request from the Contractor on a construction contract. If the Local Agency fails to pay promptly, the Local Agency shall pay interest to the Contractor, which accrues at the rate of 10 percent per annum on the principal amount of a money judgment remaining unsatisfied and pro- rated as necessary. Upon receipt of the payment request, the Local Agency shall act in accordance with both of the following:

1. The Local Agency shall review each payment request as soon as feasible after receipt to verify it is a proper payment request.

2. The Local Agency must return any payment request deemed improper by the Local Agency to the Contractor as soon as feasible, but not later than seven (7) days, after receipt. A request returned pursuant to this paragraph shall include documentation setting forth in writing the reasons why it is an improper payment request.

B. SUBMITTAL OF EXHIBIT 9-P
For projects awarded on or after September 1, 2023:

The Contractor must submit Exhibit 9-P to the Local Agency administering the contract by the 15th of the month following the month of any payment(s). If the Contractor does not make any payments to subcontractors, supplier(s) and/or manufacturers they must report “no payments were made to subs this month” and write this visibly and legibly on Exhibit 9-P.

The Local Agency must verify all Exhibit 9-P information, monitor compliance with prompt payment requirements for DBE and non-DBE firms, and address any shortfall to the DBE commitment and prompt payment issues until the end of the project. The Local Agency must email a copy of Exhibit 9- P to [email protected] before the end of the month after receiving the Exhibit 9-P from the Contractor.

10. FORM FHWA-1273 REQUIRED CONTRACT PROVISIONS FEDERAL-AID CONTRACTS [Form FHWA-1273 must be physically inserted into the contract without modification, excluding ATTACHMENT

A - EMPLOYMENT AND MATERIALS PREFERENCE FOR APPALACHIAN DEVELOPMENT HIGHWAY SYSTEM OR APPALACHIAN LOCAL ACCESS ROAD CONTRACTS.]

[The current version of Form FHWA-1273 is accessible at FHWA’s website:
https://www.fhwa.dot.gov/programadmin/contracts/1273/1273.pdf]

11. TITLE VI ASSURANCES
[The U.S. Department of Transportation Order No.1050.2A requires all federal-aid Department of Transportation contracts between an agency and a contractor to contain Appendix A and E.

Note: Appendix B only requires inclusion if the contract impacts deeds effecting or recording the transfer of real property, structures, or improvements thereon, or granting interest therein. Appendices C and D only require inclusion if the contract impacts deeds, licenses, leases, permits, or similar instruments entered into by the recipient.]

APPENDIX A

During the performance of this Agreement, the contractor, for itself, its assignees and successors in interest (hereinafter collectively referred to as CONTRACTOR) agrees as follows:
a. Compliance with Regulations: CONTRACTOR shall comply with the regulations relative to nondiscrimination in federally assisted programs of the Department of Transportation, Title 49, Code of Federal Regulations, Part 21, as they may be amended from time to time, (hereinafter referred to as the REGULATIONS), which are herein incorporated by reference and made a part of this agreement. b. Nondiscrimination: CONTRACTOR, with regard to the work performed by it during the AGREEMENT, shall not discriminate on the grounds of race, color, sex, national origin, religion, age, or disability in

EXHIBIT E

EXHIBIT 1
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language

October 2023

the selection and retention of sub-applicants, including procurements of materials and leases of equipment. CONTRACTOR shall not participate either directly or indirectly in the discrimination prohibited by Section 21.5 of the Regulations, including employment practices when the agreement covers a program set forth in Appendix B of the Regulations. c. Solicitations for Sub-agreements, Including Procurements of Materials and Equipment: In all solicitations either by competitive bidding or negotiation made by CONTRACTOR for work to be performed under a Sub- agreement, including procurements of materials or leases of equipment, each potential sub-applicant or supplier shall be notified by CONTRACTOR of the CONTRACTOR’S obligations under this Agreement and the Regulations relative to nondiscrimination on the grounds of race, color, or national origin.
d. Information and Reports: CONTRACTOR shall provide all information and reports required by theRegulations, or directives issued pursuant thereto, and shall permit access to its books, records, accounts, other sources of information, and its facilities as may be determined by the recipient or FHWA to be pertinent to ascertain compliance with such Regulations or directives. Where any information required of CONTRACTOR is in the exclusive possession of another who fails or refuses to furnish this information, CONTRACTOR shall so certify to the recipient or FHWA as appropriate, and shall set forth what efforts CONTRACTOR has made to obtain the information.
e. Sanctions for Noncompliance: In the event of CONTRACTOR’s noncompliance with the nondiscrimination provisions of this agreement, the recipient shall impose such agreement sanctions as it or the FHWA may determine to be appropriate, including, but not limited to:
i. withholding of payments to CONTRACTOR under the Agreement within a reasonable period of time, not to exceed 90 days; and/or
ii. cancellation, termination or suspension of the Agreement, in whole or in part. f. Incorporation of Provisions: CONTRACTOR shall include the provisions of paragraphs (1) through (6) in every sub-agreement, including procurements of materials and leases of equipment, unless exempt by the Regulations, or directives issued pursuant thereto.

CONTRACTOR shall take such action with respect to any sub-agreement or procurement as the recipient or FHWA may direct as a means of enforcing such provisions including sanctions for noncompliance, provided, however, that, in the event CONTRACTOR becomes involved in, or is threatened with, litigation with a sub- applicant or supplier as a result of such direction, CONTRACTOR may request the recipient enter into such litigation to protect the interests of the State, and, in addition, CONTRACTOR may request the United States to enter into such litigation to protect the interests of the United States.

APPENDIX B

CLAUSES FOR DEEDS TRANSFERRING UNITED STATES PROPERTY

The following clauses will be included in deeds effecting or recording the transfer of real property, structures, or improvements thereon, or granting interest therein from the United States pursuant to the provisions of Assurance 4:

NOW THEREFORE, the U.S. Department of Transportation as authorized by law and upon the condition that the recipient will accept title to the lands and maintain the project constructed thereon in accordance with Title 23 U.S.C., the regulations for the administration of the preceding statute, and the policies and procedures prescribed by the FHWA of the U.S. Department of Transportation in accordance and in compliance with all requirements imposed by Title 49, Code of Federal Regulations, U.S. Department of Transportation, Subtitle A, Office of the Secretary, Part 21, Non-discrimination in Federally-assisted programs of the U.S. Department of Transportation pertaining to and effectuating the provisions of Title VI of the Civil Rights Act of 1964 (78 Stat. 252; 42 U.S.C. § 2000d to 2000d-4), does hereby remise, release, quitclaim and convey unto the recipient all the right, title and interest of the U.S. Department of Transportation in and to said lands described in Exhibit A attached hereto and made a part hereof.

EXHIBIT E

EXHIBIT 1
Local Assistance Procedures Manual Exhibit 12-G
Required Federal-Aid Contract Language

October 2023

(HABENDUM CLAUSE)

TO HAVE AND TO HOLD said lands and interests therein unto the recipient and its successors forever, subject, however, to the covenants, conditions, restrictions and reservations herein contained as follows, which will remain in effect for the period during which the real property or structures are used for a purpose for which Federal financial assistance is extended or for another purpose involving the provision of similar services or benefits and will be binding on the recipient, its successors and assigns. The recipient, in consideration of the conveyance of said lands and interest in lands, does hereby covenant and agree as a covenant running with the land for itself, its successors and assigns, that (1) no person will on the grounds of race, color, or national origin, be excluded from participation in, be denied the benefits of, or be otherwise subjected to discrimination with regard to any facility located wholly or in part on, over, or under such lands hereby conveyed [,] [and]* (2) that the recipient will use the lands and interests in lands and interest in lands so conveyed, in compliance with all requirements imposed by or pursuant to Title 49, Code of Federal Regulations, U.S. Department of Transportation, Subtitle A, Office of the Secretary, Part 21, Non- discrimination in Federally-assisted programs of the U.S. Department of Transportation, Effectuation of Title VI of the Civil Rights Act of 1964, and as said Regulations and Acts may be amended[, and (3) that in the event of breach of any of the above-mentioned non-discrimination conditions, the Department will have a right to enter or re-enter said lands and facilities on said lands, and that above described land and facilities will thereon revert to and vest in and become the absolute property of the U.S. Department of Transportation and its assigns as such interest existed prior to this instruction].*

(*Reverter clause and related language to be used only when it is determined that such a clause is necessary in order to make clear the purpose of Title VI.)

APPENDIX C

CLAUSES FOR TRANSFER OF REAL PROPERTY ACQUIRED OR IMPROVED UNDER THE

ACTIVITY, FACILITY, OR PROGRAM

The following clauses will be included in deeds, licenses, leases, permits, or similar instruments entered into by the recipient pursuant to the provisions of Assurance 7(a):

A. The (grantee, lessee, permittee, etc. as appropriate) for himself/herself, his/her heirs, personal representatives, successors in interest, and assigns, as a part of the consideration hereof, does hereby covenant and agree [in the case of deeds and leases add “as a covenant running with the land”] that:

1. In the event facilities are constructed, maintained, or otherwise operated on the property described in this (deed, license, lease, permit, etc.) for a purpose for which a U.S. Department of Transportation activity, facility, or program is extended or for another purpose involving the provision of similar services or benefits, the (grantee, licensee, lessee, permittee, etc.) will maintain and operate such facilities and services in compliance with all requirements imposed by the Acts and Regulations (as may be amended) such that no person on the grounds of race, color, or national origin, will be excluded from participation in, denied the benefits of, or be otherwise subjected to discrimination in the use of said facilities.

B. With respect to licenses, leases, permits, etc., in the event of breach of any of the above Non- discrimination covenants, the recipient will have the right to terminate the (lease, license, permit, etc.) and to enter, re-enter, and repossess said lands and facilities thereon, and hold the same as if the (lease, license, permit, etc.) had never been made or issued.*

C. With respect to a deed, in the event of breach of any of the above Non-discrimination covenants, the recipient will have the right to enter or re-enter the lands and facilities thereon, and the above described lands and facilities will there upon revert to and vest in and become the absolute property of the recipient and its assigns.*

(*R
everter clause and related language to be used only when it is determined that such a clause is necessary to make clear the purpose of Title VI.)

EXHIBIT E