Vallejo City Council
September 8, 2026

19 | P a g e

4 -1.03 CHANGES

The City reserves the right without changing the scope of work, to make such alterations deviations, additions to or deletions from the drawings and Specifications, including but not limited to, the right to add or delete any portion of the work to be done with no additional compensation or change in lump sum or bid Unit Prices. The City also reserves the right without changing the scope of work, to increase or decrease the quantity of any item or portion of the work, as may be deemed by the Engineer to be necessary or advisable and to require such extra work as may be determined by the Engineer to be required for the proper completion or construction of the whole work contemplated. Such increases or decreases in quantities shall not be a basis for change in character of the work.

The City of Vallejo may request that Contractor provide City of Vallejo with estimated costs for proposed changes to the work. Contractor agrees to promptly provide City of Vallejo with detailed, itemized costs for proposed changes to the work and scheduling data demonstrating the impact, if any, of the proposed changes to the work and the time for completion. Adjustments, if any, in the amount to be paid the Contractor by reason of any modifications of the work as set forth in a Contract Change Order , Construction Change Directive, or arising from claims shall be determined by one or more of the following methods as elected by the City of Vallejo:

A. Lump Sum Price - By an acceptable lump sum price fixed in agreement between the City of Vallejo and the Contractor.

B. Unit Prices – By unit prices fixed by agreement between the City of Vallejo and the Contractor.

C. Force Account - By directing the Contractor to proceed with the work and to keep and present in such form as the City of Vallejo may direct, a correct account of the cost of the change, together with all vouchers therefore. The Contractor will be paid for labor, materials, equipment rental, etc. actually used on change order work performed under Force Account as per Section 9 -1.03 of these specifications.

The amount of payment agreed upon or, in the absence of agreement, selected by the City of Vallejo shall be set forth in the change order or construction change directive.

Upon receipt of a Contract Change Order authorized by the Engineer, the Contractor shall proceed with the ordered work. If ordered in writing by the Engineer, the Contractor shall proceed with the work so ordered prior to actual receipt of an authorized Contract Change Order therefore. In those cases, the Engineer will, as soon as practicable, issue a Contract Change Order for the ordered work and the provisions in Section 4 -1.03A, "Procedure and Protest," shall be fully applicable to the subsequently issued Contract Change Order.

When the compensation for an item of work is subject to adjustment under the provisions of Section 4-1.03, the Contractor shall, upon request, furnish the Engineer with adequate detailed cost data for that item of work.

If the Contractor requests an adjustment in compensation for an item of work, the cost data shall be submitted with the request.
4-1.03A PROCEDURE AND PROTEST

A Contract Change Order authorized by the Engineer may be issued to the Contractor at any time. Should the Contractor disagree with any terms or conditions set forth in an authorized Contract Change Order not executed by the Contractor, the Contractor shall submit a written protest to the Engineer within 15 days after the receipt of the Contract Change Order. The protest shall state the points of disagreement, and the Contract specification references, quantities and costs involved. If a written protest is not submitted, payment will be made as set forth in the Contract Change Order , and Contractor agrees that payment shall constitute full compensation for all work included therein or required thereby. Unprotested Contract Change Orders will be considered as executed Contract Change Orders.

20 | P a g e

Where the protest concerning an authorized Contract Change Order relates to compensation, the compensation payable for all work specified or required by that Contract Change Order to which the protest relates will be determined as provided in Section 4-1.03D. The Contractor shall keep full and complete records of the cost of that work and shall permit the Engineer to have access thereto as may be necessary to assist in the determination of the compensation payable for that work.

Where the protest concerning an accepted Contract Change Order relates to the adjustment of Contract time for the completion of the work, the time to be allowed therefor will be determined as provided in Section 8-1.07, "Liquidated Damages."
4-1.03B CHANGE ORDERS

Proposed Contract Change Orders may be presented to the Contractor for consideration prior to authorization by the Engineer. If the Contractor signifies acceptance of the terms and conditions of the proposed Contract Change Order by executing the document and if the Contract Change Order is accepted by the Engineer and issued to the Contractor, payment in accordance with the provisions as to compensation therein set forth shall constitute full compensation for all work included therein or required thereby. An accepted Contract Change Order shall supersede a proposed, but unaccepted, Contract Change Order covering the same work.

The Engineer may provide for an adjustment of compensation as to a Contract item of work included in a Contract Change Order determined as provided in Section 4 -1.03D if that item of work is eligible for an adjustment of compensation thereunder.

Contract Change orders shall be in the form provided by City of Vallejo in the Contract Documents. 4-1.03C (NOT USED)
4-1.03D EXTRA WORK

New and unforeseen work will be classed as extra work when determined by the Engineer that the work is not covered by any of the various items for which there is a Unit Price or by combinations of those items. In the event portions of this work are determ ined by the Engineer to be covered by some of the various items for which there is a bid price or combinations of those items, the remaining portion of the work will be classed as extra work. Extra work also includes work specifically designated as extra work in the drawings or Specifications.

The Contractor shall do the extra work and furnish all labor, material, and equipment therefor upon receipt of an accepted Contract Change Order or other written order of the Engineer, and in the absence of an accepted Contract Change Order or other written order of the Engineer the Contractor shall not be entitled to payment for the extra work.

Payment for extra work required to be performed pursuant to the provisions in this Section 4 -1.03D, in the absence of an executed Contract Change Order, will be made by force account as provided in Section 9-1.03; or as agreed to by the Contractor and the Engineer.

END OF SECTION 4

SECTION 5: CONTROL OF WORK

21 | P a g e

5-1.01 AUTHORITY OF ENGINEER

The Engineer shall decide all questions which may arise as to the quality or acceptability of materials furnished and work performed and as to the manner of performance and rate of progress of the work; all questions which may arise as to the interpretatio n of the drawings and Specifications; all questions as to the acceptable fulfillment of the Contract on the part of the Contractor; and all questions as to compensation. The Engineer's decision shall be final, and the Engineer shall have authority to enfo rce and make effective those decisions and orders which the Contractor fails to carry out promptly. 5-1.02 CONTRACT DRAWINGS AND WORKING DRAWINGS

The Contract drawings (City-approved Plans) furnished consist of general drawings and show such details as are necessary to give a comprehensive idea of the construction contemplated. All authorized alterations affecting the requirements and information given on the Contract drawings shall be in w riting.

The Contract drawings shall be supplemented by such working drawings prepared by the Contractor as are necessary to adequately control perform the work. No change shall be made by the Contractor to any working drawing after it has been accepted by the Engineer.

Working drawings for any part of the permanent work shall include, but not be limited to anchor bolt layouts, shop details, erection drawings, equipment lists, and any other information specifically required elsewhere in the Specifications.

Working drawings for falsework, temporary support systems, form work and for other temporary work and methods of construction the Contractor proposes to use, shall be submitted when required by the Contract Documents or ordered by the Engineer. Working drawings shall be subject to City of Vallejo review insofar as the details affect the character of the finished work and for compliance with design requirements applicable to the construction when specified or called for, but details of design will be left t o the Contractor who shall be responsible for the successful construction of the work.

Working drawings shall be reviewed by the Engineer before any work involving the drawings is performed. It is expressly understood that review of the Contractor's working drawings shall not relieve the Contractor of any responsibility under the Contract for the successful completion of the work in conformity with the requirements of the drawings and Specifications. Review of working drawings shall not operate to waive any of the requirements of the drawings and Specifications or relieve the Contractor of any obligation thereunder, and defective work, materials and equipment may be rejected notwithstanding the review.

Full compensation for furnishing all working drawings shall be considered as included in the prices paid for the Contract items of work to which the drawings relate, and no additional compensation will be allowed therefor. 5-1.02A TRENCH EXCAVATION SAFETY PLANS

Attention is directed to Section 7-1.01E, "Trench Safety." Excavation for any trench 1.5 m {5 feet} or more in depth shall not begin until the Contractor has prepared detailed plans for worker protection from the hazards of caving ground during the excavation of that trench. The detailed plan shall show the details of the design of shoring, br acing, sloping or other provisions to be made for worker protection during the excavation. No plan shall allow the use of shoring, sloping or a protective system less effective than that required by the Construction Safety Orders of the Division of Occupa tional Safety and Health. If the plan complies with the shoring system standards established by the Construction Safety Orders, the plan shall be submitted at least 5 days before the Contractor intends to begin excavation for the trench. If the plan vari es from the shoring system standards established by the Construction Safety Orders, the plan shall be prepared and signed by an engineer who is registered as a Civil Engineer in the State of California, and the plan and design calculations shall be submitted at least 3 weeks before the Contractor intends to begin excavation for the trench.

22 | P a g e

5-1.03 CONFORMITY WITH CONTRACT DOCUMENTS AND ALLOWABLE

DEVIATIONS

Contractor work and materials shall strictly conform to the lines, grades, typical cross sections, dimensions, and material requirements, including tolerances, required in the Contract Documents. Although measurement, sampling and testing may be considered evidence as to conformity, the Engineer shall be the sole judge as to whether the work or materials deviate from the drawings and Specifications, and the Engineer's decision as to any allowable deviations therefrom shall be final.
5-1.04 COORDINATION AND INTERPRETATION OF PLANS, SPECIFICATIONS AND

STANDARD SPECIFICATIONS

These project drawings, specifications, Special Provisions, Contract Change Order s and all supplementary documents are essential parts of the Contract, and a requirement occurring in one Contract Document is as binding as though occurring in all. They are intended to be complementary, and to describe and provide a complete work.

In the event of a conflict between the project drawings, Specifications or special provisions, and Standard Plans and Standard, Specifications of the State of California, Business, Transportation and Housing Agency, Department of Transportation, 2025 edition, City of Vallejo Standard Specifications and Standard Plans, December 2011 edition, or Vallejo Sanitation & Flood Control District Master Bid Document, 2022 edition, the project drawings, and Specifications shall control. Project drawings shall govern over Standard Plans; Standard Plans and project drawings shall govern over the Standard Specifications; and the special provisions shall govern over both the Standard Specifications and the project drawings. The specific shal l control over the general.

Should it appear that the work to be done or any of the matters relative thereto are not sufficiently detailed or explained in the Contract Documents, the Contractor shall apply in writing to the Engineer for such further explanations as may be necessary and shall conform to them as part of the Contract. In the event of any doubt or question arising respecting the true meaning of the Contract Documents, reference in writing shall be made to the Engineer, whose decision thereon shall be final.

In the event of any discrepancy between any drawing and the figures written thereon, the figures shall be taken as correct. Detail drawings shall prevail over general drawings. 5-1.05A ORDER OF WORK

When required by the Contract Documents, the Contractor shall follow the sequence of operations as set forth therein.

Full compensation for conforming to those requirements will be considered as included in the prices paid for the various Contract items of work and no additional compensation will be allowed therefor. 5-1.05B HOURS OF WORK
Regular working hours are 8:00 a.m. to 5:00 p.m., Monday through Friday, excluding holidays observed by the City. For work to be completed within the State Right of Way, regular working hours are 7:00 p.m. to 7:00 a.m.

No work outside of the regular working hours shall be done unless previously re quested by the Contractor in writing and approved by the Engineer in writing. The contractor is subject to reimbursing the City for the costs of providing inspection outside of regular working hours.

No work shall take place on garbage collection days. Contractor shall coordinate with Recology to verify garbage collection schedule.

23 | P a g e

5-1.06 SUPERINTENDENCE

The Contractor shall designate in writing before starting work an authorized representative who shall act as Superintendent and have the authority to represent and act for the Contractor. The Superintendent shall have responsibility for overall project operations and shall not be a “working foreman.”

When the Contractor is comprised of 2 or more persons, firms, partnerships, or corporations functioning on a joint venture basis, the Contractor shall designate in writing before starting work, the name of one authorized representative who shall serve as t he Superintendent, and who shall have the authority to represent and act for the Contractor.

The Superintendent shall be always present at the site of the work while work is in progress on the Contract.

When work is not in progress and during periods when work is suspended, arrangements acceptable to the Engineer shall be made for any emergency work which may be required.

Whenever the Contractor or the Contractor's Superintendent is not present on any part of the work where it may be desired to give direction, orders will be given by the Engineer, which shall be received and obeyed by the foreman or other individual who may have charge of the particular work in reference to which the orders are given.

Any order given by the Engineer, not otherwise required by the Specifications to be in writing, will on request of the Contractor, be given or confirmed by the Engineer in writing. 5-1.07 LINES AND GRADES
Stakes or marks for horizontal and vertical control will be set by the Engineer as the Engineer determines to be necessary to establish the lines and grades required for the completion of the work specified in these Contract Documents.

When the Contractor requires the stakes or marks, the Contractor shall notify the Engineer of the requirements in writing a reasonable length of time in advance of starting operations that require the stakes or marks. In no event shall a notice of less than 2 working days be considered a reasonable length of time.

Stakes and marks set by the Engineer shall be carefully preserved by the Contractor. In case the stakes and marks are destroyed or damaged, the Contractor will be charged for the cost of necessary replacement or restoration of stakes and marks. This char ge will be deducted from any moneys due or to become due the Contractor.
5-1.08 INSPECTION

The Engineer shall at all times have safe access to the work during its construction and shall be furnished with every reasonable facility for ascertaining that the materials and the workmanship are in accordance with the requirements and intentions of the Contract Documents. All work done and all materials furnished shall be subject to the Engineer's inspection.

Neither the inspection by an inspector, City of Vallejo, Engineer, nor any measurement, approved or unapproved modification, submittals, shop drawing, order, or certificate, nor acceptance of any part or whole of the work, or payment of money, nor any possession or use by the City of Vallejo or its agents, shall operate as a waiver of any provisions of the Contract or of any power or authority reserved therein, or of any right to damages thereunder; nor shall the waiver of any breach of this Contract be hel d to be a waiver of any subsequent or other breach.

Projects financed in whole or in part with State or Federal funds shall at all times be subject to inspection by the State or Federal agency involved, or their authorized representative.

24 | P a g e

5-1.09 REMOVAL OF REJECTED AND UNAUTHORIZED WORK

All work which has been rejected shall be remedied or removed and replaced by the Contractor in a manner acceptable to the Engineer, and no compensation will be allowed to the Contractor for the removal, replacement or remedial work.

Any work done beyond the lines and grades shown on the drawings or established by the Engineer, or any extra work done without written authority will be considered as unauthorized work and will not be paid for.

Upon order of the Engineer unauthorized work shall be remedied, removed, or replaced at the Contractor's expense.

Upon failure of the Contractor to comply promptly with any order of the Engineer made under this Section 5 -

1.09, the City of Vallejo may cause rejected or unauthorized work to be remedied, removed, or replaced, and to deduct the costs from any moneys due or to become due the Contractor. 5-1.10 EQUIPMENT AND PLANTS

Only equipment suitable to produce the quality of work and materials required will be permitted to operate on the project.

The Contractor shall provide adequate and suitable equipment and plants to meet the above requirements, and when ordered by the Engineer shall remove unsuitable equipment from the work and discontinue the operation of unsatisfactory plants.

The Contractor shall identify each piece of equipment, other than hand tools, by means of an identifying number plainly stenciled or stamped on the equipment at a conspicuous location and shall furnish to the Engineer a list giving the description of each piece of equipment and its identifying number. 5-1.11 ALTERNATIVE EQUIPMENT

While certain of the Contract Documents may provide that equipment of a particular size and type is to be used to perform portions of the work, it is to be understood that the development and use of new or improved equipment is to be encouraged.

The Contractor may request, in writing, permission from the Engineer to use equipment of a different size or type in place of the equipment specified.

The Engineer, before considering or granting the request, may require the Contractor to furnish, at the Contractor's expense, evidence satisfactory to the Engineer that the equipment proposed for use by the Contractor is capable of producing work equal to, or better than, that which can be produced by the equipment specified.

If permission is granted by the Engineer, it shall be understood that the permission is granted for the purpose of testing the quality of work produced by the equipment and is subject to continuous attainment of results which, in the opinion of the Engineer, are equal to, or better than, that which can be obtained with the equipment specified. The Engineer shall have the right to withdraw permission at any time that the Engineer determines that the alternative equipment is not producing work that is equal, in all respects, to that which can be produced by the equipment specified. Upon withdrawal of permission by the Engineer, the Contractor will be required to use the equipment originally specified and shall, in accordance with the directions of the Engine er, remove and dispose of or otherwise remedy, at the Contractor's expense, any defective or unsatisfactory work produced with the alternative equipment.

The Contractor shall not have any claim against the City of Vallejo for either the withholding or the granting of permission to use alternative equipment, or for the withdrawal of the permission.

25 | P a g e

Permission to use alternative equipment in place of equipment specified will only be granted where the equipment is new or improved and its use is deemed by the Engineer to be in furtherance of the purposes of this Section 5-1.11. Permission for use of pa rticular equipment on any project shall in no way be considered as permission of the use of the equipment on any other project.

Nothing in this Section 5 -1.11 shall relieve the Contractor of the responsibility for furnishing materials or producing finished work of the quality specified in the Contract Documents . 5-1.12 ALTERNATIVE METHODS OF CONSTRUCTION
Whenever the drawings or Specifications provide that more than one specified method of construction or more than one specified type of material or construction equipment may be used to perform portions of the work and leave the selection of the method of c onstruction or the type of material or equipment to be used up to the Contractor, it is understood that the City of Vallejo does not guarantee that every or any specified method of construction or type of material or equipment can be used successfully throughout all or any part of any project.

It shall be the Contractor's responsibility to select and use the alternative or alternatives which will satisfactorily perform the work under the conditions encountered. In the event some of the alternatives are not feasible or it is necessary to use more than one of the alternatives on any project, full compensation for any additional cost involved shall be considered as included in the Contract price paid for the item of work involved and no additional compensation will be allowed therefor.
5-1.13 DIFFERING SITE CONDITIONS

During the progress of the work, if subsurface or latent physical conditions are encountered at the site differing materially from those indicated in the Contract or if unknown physical conditions of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent in the work provided for in the Contract, are encountered at the site, the Contractor shall promptly notify the Engineer in writing of the specific differing conditions before they are disturbed and before the affected work is performed.

Upon written notification, the Engineer will investigate the conditions, and if the Engineer determines that the conditions materially differ and cause an increase or decrease in the cost or time required for the performance of any work under the Contract, an adjustment, excluding loss of anticipated profits, will be made and the Contract modified in writing accordingly. The Engineer will notify the Contractor of the Engineer's determination whether an adjustment of the Contract is warranted.

No Contract adjustment which results in a benefit to the Contractor will be allowed unless the Contractor has provided the required written notice. Contractor agrees that failure to provide written notice to Engineer as required herein, or failure to othe rwise abide by this Section, shall be a waiver by Contractor of any claim, demand, compensation or adjustment in the Contract time or working days.

No Contract adjustment will be allowed under the provisions specified in this section for any effects caused on unchanged work.

Any Contract adjustment warranted due to differing site conditions will be made in conformance with the provisions in Section 4-1.03, "Changes," except as otherwise provided. 5-1.14 CHARACTER OF WORKERS

If any subcontractor or person employed by the Contractor shall appear to the Engineer to be incompetent or to act in a disorderly or improper manner, they shall be discharged immediately on the request of the Engineer, and that person shall not again be employed on the work.

5-1.15 FINAL INSPECTION

26 | P a g e

When the work has been completed, the Engineer will make the final inspection. 5-1.16 MEANS AND METHODS

City of Vallejo will not have control over, oversee, nor be responsible for construction means, methods, techniques, sequences, or procedures, or for the safety precautions and programs in connection with the work, since these are solely Contractor's responsibility.

The City of Vallejo may perform other work adjacent to or within the project area, concurrent with the Contractor's operations. The Contractor shall cooperate fully with City of Vallejo in all operations which coincide with other work being performed and provide City of Vallejo with such scheduling and other information as may be required by City of Vallejo to perform such other work. The Contractor shall conduct operations to minimize interference with the work of other forces or contractors performing s uch work. This work performed by a second contractor may include work which is incomplete or in dispute with the Contractor.

Any disputes or conflicts which may arise between the Contractor and any other forces or contractors retained by the City of Vallejo, causing delays or hindrance to each other, shall be referred to the Engineer for resolution.

The City of Vallejo shall have the right at any time during the progress of this work to take over and place in service any completed or partially completed portion of the work, notwithstanding the time for completion of the entire work or such portions wh ich may not have expired; but such taking possession thereof shall not be deemed an acceptance of any of the work, nor work on those portions not completed in accordance with the Contract Documents.

END OF SECTION 5

27 | P a g e

SECTION 6: CONTROL OF MATERIALS
6-1 GENERAL
6-1.01 SOURCE OF SUPPLY AND QUALITY OF MATERIALS

The Contractor shall furnish all materials required to complete the work, except materials that are designated in the Specifications to be furnished by the City of Vallejo and materials furnished by the City of Vallejo in conformance with the provisions in Section 9-1.03, "Force Account Payment."

Only materials conforming to the requirements of the Contract Documents shall be incorporated in the work.

The materials furnished and used shall be new, except as may be provided elsewhere in the Contract Documents. The materials shall be manufactured, handled and used in a workmanlike manner to ensure completed work in accordance with the drawings and Specifications.

Materials to be used in the work will be subject to inspection and tests by the Engineer or the Engineer's designated representative. The Contractor shall furnish without charge such samples as may be required.

The Contractor shall furnish the Engineer a list of the Contractor's sources of materials and the locations at which those materials will be available for inspection. The list shall be submitted on a form acceptable to the Engineer and shall be furnished to the Engineer in sufficient time to permit inspecting and testing of materials to be furnished to the listed sources in advance of their use. The Engineer may inspect, sample or test materials at the source of supply or other locations, but the inspecti on, sampling or testing will not be undertaken until the Engineer is assured by the Contractor of the cooperation and assistance of both the Contractor and the supplier of the material. The Contractor shall assure that the Engineer or the Engineer's authorized representative has free access at all times to the material to be inspected, sampled or tested. It is understood that the inspections and tests if made at any point other than the point of incorporation in the work in no way shall be considered as a guaranty of acceptance of the material nor of continued acceptance of material presumed to be similar to that upon which inspections and tests have been made, and that inspection and testing performed by the City of Vallejo shall not relieve the Contracto r or the Contractor's suppliers of responsibility for quality control.

Manufacturers' warranties, guaranties, instruction sheets and parts lists, which are furnished with certain articles or materials incorporated in the work, shall be delivered to the Engineer before acceptance of the Contract.

Reports and records of inspections made, and tests performed, when available at the site of the work, may be examined by the Contractor.
6-1.02 CITY FURNISHED MATERIALS

Materials which are listed as City of Vallejo-furnished materials in the special provisions will be available to the Contractor free of charge.

The Contractor shall submit a written request to the Engineer for the delivery of City of Vallejo -furnished material at least 15 days in advance of the date of its intended use. The request shall state the quantity and the type of each material.

The City of Vallejo-furnished materials will be available to the Contractor free of charge will be designated in the special provisions. In those cases the materials shall be hauled to the site of the work by the Contractor at the Contractor's expense, including any necessary loading and unloading that may be involved. All costs of handling and placing City of Vallejo-furnished material shall be considered as included in the price paid for the Contract item involving the City of Vallejo-furnished material.

28 | P a g e

The Contractor shall be responsible for all City of Vallejo -furnished materials furnished to the Contractor, and shall pay all demurrage and storage charges. City of Vallejo -furnished materials lost or damaged from any cause whatsoever shall be replaced b y the Contractor at the Contractor's expense. The Contractor shall be liable to the City of Vallejo for the cost of replacing City of Vallejo -furnished material, and those costs may be deducted from any moneys due or to become due the Contractor. All City of Vallejo -furnished material that is not used on the work shall remain the property of the City of Vallejo and shall be delivered to the Eng ineer’s designated location at no cost to the City.

6-1.03 STORAGE OF MATERIALS

Articles or materials to be incorporated in the work shall be stored in such a manner as to ensure the preservation of their quality and fitness for the work, and to facilitate inspection.

6-1.04 DEFECTIVE MATERIALS

All materials which the Engineer has determined do not strictly conform to the requirements of the Contract Documents will be rejected whether in place or not. The rejected materials shall be removed immediately from the site of the work, unless otherwise permitted in writing by the Engineer. No rejected material, the defects of which have been subsequently corrected, shall be used in the work, unless authorization in writing has been given by the Engineer. Upon failure of the Contractor to comply promptly with any order of the Engineer made under the provisions in this section, the Engineer shall have authority to cause the removal and replacement of rejected material and to deduct the cost thereof from any moneys due or to become due the Contractor.

If nonconforming work, materials, or equipment not meeting the requirements and intent of the Contract Documents is discovered, and the Contractor fails to remedy the nonconforming work, materials, or equipment, or the City of Vallejo agrees in writing to accept the nonconforming work, materials, or equipment, Contractor agrees to sign a Contract Change Order or otherwise reimburse City of Vallejo in a sum equal to the cost to remedy the nonconforming work, materials, or equipment. It is expressly understood and agreed that the City of Vallejo will be entitled to recover from Contractor the full cost of remed ying nonconforming work, materials, or equipment, and that diminution in value will not be considered as a method for valuing the City of Vallejo's damages for nonconforming work, materials, or equipment, and further that the doctrine of economic waste will not be a defense to the City of Vallejo's recovery from Contractor of the full and complete cost and expense of remedying nonconforming work, materials, or equipment.

Re-examination of any work may be ordered by the Engineer, and such work must be uncovered by the Contractor. The Contractor shall pay the entire cost of such uncovering, re -examination, and replacement if the work does not conform to the Contract Documents.

6-1.05 TRADE NAMES AND ALTERNATIVES

For convenience in designation on the Contract Documents, certain articles or materials to be incorporated in the work may be designated under a trade name or the name of a manufacturer and the manufacturer's catalogue information. The use of an alternative article or material which is of equal or superior quality and of the required characteristics for the purpose intended will be permitted, subject to the following requirements:

The burden of proof as to the quality and suitability of alternatives shall be upon the Contractor, and the Contractor shall furnish all information necessary as required by the Engineer. The Engineer shall be the sole judge as to the quality and suitabil ity of alternative articles or materials, and the Engineer's decision shall be final.

29 | P a g e

Whenever the Contract Documents permit the substitution of a similar or equivalent material or article, no tests or action relating to the acceptance of the substitute material will be made until the request for substitution is made in writing by the Contr actor accompanied by complete data as to the equality of the material or article proposed. Request for such substitution shall be made in writing by the Contractor within thirty (30) days of the Notice to Proceed. Failure by the Contractor to request substitution within thirty (30) days of the Notice to Proceed constitutes an agreement by Contractor to furnish only the materials or equipment listed in the Contract Documents. Until and unless such substitutions are authorized in writing by the Engineer, n o deviations from the specifications shall be allowed.
6-1.06 PLANT INSPECTION

The Engineer may inspect the production of material or the manufacture of products at the source of supply.

Plant inspection, however, will not be undertaken until the Engineer is assured of the cooperation and assistance of both the Contractor and the material producer. The Engineer or the Engineer's authorized representative shall have free entry at all times to those parts of the plant as concerns the manufacture or production of the materials. Adequate facilities shall be furnished free of charge to make the necessary inspection. The City of Vallejo assumes no obligation to inspect materials at the source of supply. 6-1.07 CERTIFICATES OF COMPLIANCE

A Certificate of Compliance shall be furnished prior to the use of any materials for which the Contract Documents require that a certificate be furnished. In addition, when so authorized in the Contract Documents, the Engineer may permit the use of certai n materials or assemblies prior to sampling and testing if accompanied by a Certificate of Compliance. The certificate shall be signed by the manufacturer of the material or the manufacturer of assembled materials and shall state that the materials involv ed comply in all respects with the requirements of the Contract Documents. A Certificate of Compliance shall be furnished with each lot of material delivered to the work and the lot so certified shall be clearly identified in the certificate.

Materials used on the basis of a Certificate of Compliance may be sampled and tested at any time. The fact that material is used on the basis of a Certificate of Compliance shall not relieve the Contractor of responsibility for incorporating material in the work which conforms to the requirements of the Contract Documents, and any material not conforming to the requirements will be subject to rejection whether in place or not.

The City of Vallejo reserves the right to refuse to permit the use of material on the basis of a Certificate of Compliance.

The form of the Certificate of Compliance and its disposition shall be as directed by the Engineer. 6-1.08 FOREIGN MATERIALS

Materials which are manufactured, produced or fabricated outside of the United States shall be delivered to a distribution point in California, unless otherwise required in the Contract Documents, where they shall be retained for a sufficient period of time to permit inspection, sampling and testing.

Attention is directed to the provisions in Section 8 -1.07, "Liquidated Damages." The Contractor shall not be entitled to an extension of time for acts or events occurring outside of the United States, and it shall be the Contractor's responsibility to deliver materials obtained from outside of the United St ates to the point of entry into the continental United States in sufficient time to permit timely delivery to the job site.

The Contractor, at no cost to the City of Vallejo, shall supply the facilities and arrange for any testing required in California which the City of Vallejo is not equipped to perform. All testing by the Contractor shall be subject to witnessing by the Engineer.

The manufacturer, producer or fabricator of foreign material shall furnish to the Engineer a Certificate of

30 | P a g e

Compliance in conformance with the provisions in Section 6 -1.07, "Certificates of Compliance." In addition, certified mill test reports clearly identifiable to the lot of material shall be furnished where required in the Contract Documents or otherwise requested by the Engineer.

If the welding of steel for structural steel members or the casting and prestressing of precast, prestressed concrete members is to be performed outside of the United States, the following requirements shall apply:

A. The fabrication shall be performed only within the plants and by fabricators who have previously established, to the satisfaction of the Engineer, that they have the experience, knowledge, trained manpower, quality controls, equipment and other facilities required to produce the quality and quantity of work required. At the option of the Engineer, prequalification of the plant and fabricator will be established either by the submission of detailed written proof thereof or through in-plant inspection by the Engineer or the Engineer's representative, or both.

B. The Contractor shall make written application to the Engineer for acceptance for the foreign fabrication at the earliest possible time and in no case later than 50 days in advance of the planned start of fabrication. The application shall list the specif ic units or portion of a work which will be fabricated outside of the United States.

C. The Contractor shall advise the Engineer, in writing, at least 20 days in advance of the actual start of any of the foreign fabrication.

D. All documents pertaining to the Contract, including but not limited to, correspondence, bid documents, working drawings and data shall be written in the English language and all numerical data shall use the International System of Units (SI) {United States Standard Measures} for measurement.

The use of steel manufactured outside of the United States as unidentified stock material, as provided in Section 55-2.07, "Unidentified Stock Material," will not be allowed.

END OF SECTION 6

31 | P a g e

SECTION 7: LEGAL RELATIONS AND RESPONSIBILITY
7-1.01 LAWS TO BE OBSERVED

The Contractor shall keep fully informed of all existing and future laws, ordinances and regulations which in any manner affect those engaged or employed in the work, or the materials used in the work, or which in any way affect the conduct of the work, and of all orders and decrees of bodies or tribunals having any jurisdiction or authority over the same. The Contractor shall at all times observe and comply with, and shall cause all the Contractor's agents, employees, subcontractors and material suppliers to observe and comply with all existing and future laws, ordinances, regulations, orders and decrees of bodies or tribunals having any jurisdiction or authority over the work; and shall protect and indemnify the City of Vallejo, and all officers and emplo yees thereof connected with the work, including but not limited to the Director and the Engineer, against any claim or liability arising from or based on the violation of any law, ordinance, regulation, order or decree, whether by the Contractor or the Contractor's employees. If any discrepancy or inconsistency is discovered in the Contract Documents for the work in relation to any law, ordinance, regulation, order or decree, each Bidder and the Contractor shall forthwith report the same to the Engineer in writing. 7-1.01A LABOR CODE REQUIREMENTS

Attention is directed to the following requirements of the Labor Code:
7-1.01A (1) HOURS OF LABOR

Eight hours of labor constitutes a legal day's work. The Contractor or any subcontractor under the Contractor shall forfeit, as a penalty to the State of California, $25 for each worker employed in the execution of the Contract by the respective Contracto r or subcontractor for each calendar day during which that worker is required or permitted to work more than 8 hours in any one calendar day and 40 hours in any one calendar week in violation of the requirements of the Labor Code, and in particular, Sectio n 1810 to Section 1815, thereof, inclusive, except that work performed by employees of Contractors in excess of 8 hours per day, and 40 hours during any one week, shall be permitted upon compensation for all hours worked in excess of 8 hours per day at not less than one and one-half times the basic rate of pay, as provided in Section 1815 thereof. 7-1.01A (2) PREVAILING WAGE

The Contractor and any subcontractor under the Contractor shall comply with Labor Code Sections 1774 and 1775. Pursuant to Section 1775, the Contractor and any subcontractor under the Contractor shall forfeit to the City of Vallejo or political subdivision on whose behalf the Contract is made or awarded a penalty of not more than fifty dollars ($50) for each calendar day, or portion thereof, for each worker paid less than the prevailing rates as determined by the Director of Industrial Relations for the work or craft in which the worker is employed for any public work done under the Contract by the Contractor or by any subcontractor under the Contractor in violation of the requirements of the Labor Code and in particular, Labor Code Sections 1770 to 1780, inclusive.

The amount of this forfeiture shall be determined by the Labor Commissioner and shall be based on consideration of the mistake, inadvertence, or neglect of the Contractor or subcontractor in failing to pay the correct rate of prevailing wages, o r the previous record of the Contractor or subcontractor in meeting their respective prevailing wage obligations, or the willful failure by the Contractor or subcontractor to pay the correct rates of prevailing wages. A mistake, inadvertence, or neglect i n failing to pay the correct rate of prevailing wages is not excusable if the Contractor or subcontractor had knowledge of the obligations under the Labor Code. In addition to the penalty and pursuant to Labor Code Section 1775, the difference between the prevailing wage rates and the amount paid to each worker for each calendar day or portion thereof for which

32 | P a g e

each worker was paid less than the prevailing wage rate shall be paid to each worker by the Contractor or subcontractor. If a worker employed by a subcontractor on a public works project is not paid the general prevailing per diem wages by the subcontractor, the prime Contractor of the project is not liable for the penalties described above unless the prime Contractor had knowledge of that failure of the subcontractor to pay the specified prevailing rate of wages to those workers or unless the prime Contra ctor fails to comply with all of the following requirements:

A. The Contract executed between the Contractor and the subcontractor for the performance of work on the public works project shall include a copy of the requirements in Sections 1771, 1775, 1776, 1777.5, 1813 and 1815 of the Labor Code.

B. The Contractor shall monitor the payment of the specified general prevailing rate of per diem wages by the subcontractor to the employees, by periodic review of the certified payroll records of the subcontractor.

C. Upon becoming aware of the subcontractor's failure to pay the specified prevailing rate of wages to the subcontractor's workers, the Contractor shall diligently take corrective action to halt or rectify the failure, including, but not limited to, retaining sufficient funds due the subcontractor for work performed on the public works project.

D. Prior to making final payment to the subcontractor for work performed on the public works project, the Contractor shall obtain an affidavit signed under penalty of perjury from the subcontractor that the subcontractor has paid the specified general prevail ing rate of per diem wages to the subcontractor's employees on the public works project and any amounts due pursuant to Section 1813 of the Labor Code.

Pursuant to Section 1775 of the Labor Code, the Division of Labor Standards Enforcement shall notify the Contractor on a public works project within 15 days of the receipt by the Division of Labor Standards Enforcement of a complaint of the failure of a su bcontractor on that public works project to pay workers the general prevailing rate of per diem wages. If the Division of Labor Standards Enforcement determines that employees of a subcontractor were not paid the general prevailing rate of per diem wages and if the City of Vallejo did not retain sufficient money under the Contract to pay those employees the balance of wages owed under the general prevailing rate of per diem wages, the Contractor shall withhold an amount of moneys due the subcontractor sufficient to pay those employees the general prevailing rate of per diem wages if requested by the Division of Labor Standards Enforcement. The Contractor shall pay any money retained from and owed to a subcontractor upon receipt of notification by the Divis ion of Labor Standards Enforcement that the wage complaint has been resolved. If notice of the resolution of the wage complaint has not been received by the Contractor within 180 days of the filing of a valid notice of completion or acceptance of the public works project, whichever occurs later, the Contractor shall pay all moneys retained from the subcontractor to the City of Vallejo. These moneys shall be retained by the City of Vallejo pending the final decision of an enforcement action.

Pursuant to the requirements in Section 1773 of the Labor Code, the City of Vallejo has obtained the general prevailing rate of wages (which rate includes employer payments for health and welfare, pension, vacation, travel time and subsistence pay as prov ided for in Section 1773.8 of the Labor Code, apprenticeship or other training programs authorized by Section 3093 of the Labor Code, and similar purposes) applicable to the work to be done, for straight time, overtime, Saturday, Sunday and holiday work. The holiday wage rate listed shall be applicable to all holidays recognized in the collective bargaining agreement of the particular craft, classification or type of workmen concerned.

General prevailing wage rates are also available from the California State Department of Industrial Relations' Internet Web Site at:
http://www.dir.ca.gov/OPRL/dprewagedetermination.htm

The wage rates determined by the Director of Industrial Relations for the project refer to expiration dates.

Prevailing wage determinations with a single asterisk after the expiration date are in effect on the date of advertisement for bids and are good for the life of the Contract. Prevailing wage determinations with double

33 | P a g e

asterisks after the expiration date indicate that the wage rate to be paid for work performed after this date has been determined. If work is to extend past this date, the new rate shall be paid and incorporated in the Contract.

The Contractor shall cont act the Department of Industrial Relations as indicated in the wage rate determinations to obtain predetermined wage changes.

Pursuant to Section 1773.2 of the Labor Code, general prevailing wage rates shall be posted by the Contractor at a prominent place at the site of the work.

Changes in general prevailing wage determinations which conform to Labor Code Section 1773.6 and Title 8 California Code of Regulations Section 16204 shall apply to the project when issued by the Director of Industrial Relations at least 10 days prior to the date of the Notice to Contractors for the project.

The City of Vallejo will not recognize any claim for additional compensation because of the payment by the Contractor of any wage rate in excess of the prevailing wage rate set forth in the Contract. The possibility of wage increases is one of the element s to be considered by the Contractor in determining the bid and will not under any circumstances be considered as the basis of a claim against the City of Vallejo on the Contract by Contractor.
7-1.01A(2)(A) TRAVEL AND SUBSISTENCE PAYMENTS

Attention is directed to the requirements in Section 1773.8 of the Labor Code. The Contractor shall make travel and subsistence payments to each workman, needed to execute the work, in conformance with the requirements in Labor Code Section 1773.8.

Full compensation for conforming to the requirement of this section shall be considered as included in the prices paid for the various contract items of work involved and no additional compensation will be allowed, therefore.
7-1.01A(3) PAYROLL RECORDS

Attention is directed to the requirements in Labor Code Section 1776, a portion of which is quoted below.

Regulations implementing Labor Code Section 1776 are located in Sections 16016 through 16019 and Sections 16207.10 through 16207.19 of Title 8, California Code of Regulations.

A. Each Contractor and subcontractor shall keep accurate payroll records, showing the name, address, social security number, work classification, straight time and overtime hours worked each day and week, and the actual per diem wages paid to each journeyman, apprentice, worker, or other employee employed by him or her in connection with the public work. Each payroll record shall contain or be verified by a written declaration that it is made under penalty of perjury, stating both of the following:

1. The information contained in the payroll record is true and correct.

2. The employer has complied with the requirements of Sections 1771, 1811, and 1815 for any work performed by his or her employees on the public works project.

B. The payroll records enumerated under subdivision (a) shall be certified and shall be available for inspection at all reasonable hours at the principal office of the Contractor on the following basis:

1. A certified copy of an employee's payroll record shall be made available for inspection or furnished to the employee or his or her authorized representative on request.

2. A certified copy of all payroll records enumerated in subdivision (a) shall be made available for inspection or furnished upon request to a representative of the body awarding the Contract, the Division of Labor Standards Enforcement, and the Division of Apprenticeship Standards of the Department of Industrial Relations.

34 | P a g e

3. A certified copy of all payroll records enumerated in subdivision (a) shall be made available upon request by the public for inspection or for copies thereof. However, a request by the public shall be made through either the body awarding the Contract, th e Division of Apprenticeship Standards, or the Division of Labor Standards Enforcement. If the requested payroll records have not been provided pursuant to paragraph (2), the requesting party shall, prior to being provided the records, reimburse the costs of preparation by the Contractor, subcontractors, and the entity through which the request was made. The public shall not be given access to the records at the principal office of the Contractor.

C. The certified payroll records shall be on forms provided by the Division of Labor Standards Enforcement or shall contain the same information as the forms provided by the division.

D. A Contractor or subcontractor shall file a certified copy of the records enumerated in subdivision (a) with the entity that requested the records within 10 days after receipt of a written request.

E. Any copy of records made available for inspection as copies and furnished upon request to the public or any public agency by the awarding body, the Division of Apprenticeship Standards, or the Division of Labor Standards Enforcement shall be marked or obliterated in a manner so as to prevent disclosure of an individual's name, address and social security number. The name and address of the Contractor awarded the Contract or the subcontractor performing the Contract shall not be marked or obliterated.

F. The Contractor shall inform the body awarding the Contract of the location of the records enumerated under subdivision (a), including the street address, city and county, and shall, within five working days, provide a notice of a change of location and address.

G. The Contractor or subcontractor shall have 10 days in which to comply subsequent to receipt of a written notice requesting the records enumerated in subdivision (a). In the event that the Contractor or subcontractor fails to comply within the 10 -day period, he or she shall, as a penalty to the state or political subdivision on whose behalf the Contract is made or awarded, forfeit twenty-five dollars ($25) for each calendar day, or portion thereof, for each worker, until strict compliance is effectuated. Upon the request of the Division of Apprenticeship Standards or the Division of Labor Standards Enforcement, these penalties shall be withheld from progress payments then due. A Contractor is not subject to a penalty assessment pursuant to this section due to the failure of a subcontractor to comply with this section."

The penalties specified in subdivision (g) of Labor Code Section 1776 for noncompliance with the requirements in Section 1776 may be deducted from any moneys due or which may become due to the Contractor.

All contractors and subcontractors must furnish electronic certified payroll records directly to the Labor Commissioner (aka Division of Labor Standards Enforcement). Payrolls shall contain the full name, address and social security number of each employe e, the employee's correct classification, rate of pay, daily and weekly number of hours worked, itemized deductions made and actual wages paid. They shall also indicate apprentices and ratio of apprentices to journeymen. The employee's address and social security number need only appear on the first payroll on which that name appears. The payroll shall be accompanied by a "Statement of Compliance" signed by the employer or the employer's agent indicating that the payrolls are correct and complete and tha t the wage rates contained therein are not less than those required by the Contract. The "Statement of Compliance" shall be on forms furnished by the City of Vallejo or on any form with identical wording. The Contractor shall be responsible for the submission of copies of payrolls of all subcontractors.

If by the 15th of the month, the Contractor has not submitted satisfactory payrolls for all work performed during the monthly period ending on or before the 1st of that month, the City of Vallejo may retain an amount equal to 10 percent of the estimated va lue of the work performed (exclusive of Mobilization) during the month from the next monthly estimate, except that this retention shall not exceed $10,000 nor be less than $1,000.

Retentions for failure to submit satisfactory payrolls shall be additional to all other retentions provided for in the Contract. The retention for failure to submit payrolls for any monthly period will be released for payment on the monthly estimate for partial payments next following the date that all the satisfactory payrolls for which the retention was made are submitted.

35 | P a g e

The Contractor and each subcontractor shall preserve their payroll records for a period of 3 years from the date of completion of the Contract.
7-1.01A(4) LABOR NONDISCRIMINATION

Attention is directed to Section 1735 of the Labor Code, which reads as follows:

"No discrimination shall be made in the employment of persons upon public works because of the race, religious creed, color, national origin, ancestry, physical handicap, medical condition, marital status, or sex of such persons, except as provided in Section 12940 of the Government Code, and every Contractor for public works violating this section is subject to all the penalties imposed for a violation of this chapter."

Attention is directed to the following "Nondiscrimination Clause" that is required by Chapter 5 of Division 4 of Title 2, California Code of Regulations.

NONDISCRIMINATION CLAUSE

“During the performance of this Contract, Contractor and its SUBCONTRACTORS shall not unlawfully discriminate against any employee or applicant for employment because of race, religion, color, national origin, ancestry, physical handicap, medical condition , marital status, age (over 40) or sex. Contractors and SUBCONTRACTORS shall ensure that the evaluation and treatment of their employees and applicants for employment are free of such discrimination. Contractors and SUBCONTRACTORS shall comply with the provisions of the Fair Employment and Housing Act (Gov. Code, Section 12990 et seq.) and the applicable regulations promulgated thereunder (California Code of Regulations, Title 2, and Section 7285.0 et seq.). The applicable regulations of the Fair Employm ent and Housing Commission implementing Government Code, Section 12990, set forth in Chapter 5 of Division 4 of Title 2 of the California Code of Regulations are incorporated into this Contract by reference and made a part hereof as if set forth in full. Contractor and its SUBCONTRACTORS shall give written notice of their obligations under this clause to labor organizations with which they have a collective bargaining or other agreement.”

The Contractor shall include the nondiscrimination and compliance provisions of this clause in all subcontracts to perform work under the Contract.
7-1.01A(5) APPRENTICES

Attention is directed to Sections 1777.5, 1777.6 and 1777.7 of the California Labor Code and Title 8, California Code of Regulations Section 200 et seq. To ensure compliance and complete understanding of the law regarding apprentices, and specifically the required ratio thereunder, each Contractor or subcontractor should, where some question exists, contact the Division of Apprenticeship Standards, 455 Golden Gate Avenue, San Francisco, CA 94102, or one of its branch offices prior to commencement of work on the public works Contract.

Responsibility for compliance with this section lies with the Contractor.

It is City of Vallejo policy to encourage the employment and training of apprentices on public works Contracts as may be permitted under local apprenticeship standards.

A. Only registered apprentices within a written agreement in an approved apprentice -training program providing no less than 2,000 hours of continuous employment and education are eligible for employment on public works (in compliance with Labor Section 3077).

B. A contractor is no longer required to submit Form DAS -7, but must submit award information to the local applicable joint apprenticeship committee. The award information must include:

• an estimate of the journeyman hours;

36 | P a g e

• the number of apprentices to be employed; and

• the approximate dates of apprentice employment.

C. The minimum statutory 1:5 hourly ratio of work stipulates that no less than one hour of apprentice work for every five hours of journeyman labor on any day of work. (Any journeyman work performed beyond 8 hours per day or 40 hours per week shall not be used to calculate the hourly ratio). This section shall not apply to specialty contractors or general contractors whose contracts involve less than Thirty Thousand Dollars ($30,000.00) or 20 working days.

The Division of Apprenticeship Standards may grant a certificate exempting the contractor from the minimum 1:5 hourly ratios under any one of the following:

Unemployment exceeds an average of 15% in the area for the previous 3-month period;

The number of apprentices in training in such area exceeds a ratio of 1:5;

The apprentice able craft or trade is replacing at least one-thirtieth of its journeymen annually through apprenticeship training, either locally or statewide;

The specific task would jeopardize the apprentice's life or public safety or no training can be provided to an apprentice by a journeyman for the specific task.

D. Apprentices employed on public works projects can only be assigned to perform work of the craft or trade to which the apprentice is registered.

E. All contractors with employees in any apprentice able occupation, regardless of the actual employment of journeymen or apprentices for the awarded public work, must either contribute to the local training trust fund or to the California Apprenticeship Council, P.O. Box 603, San Francisco, CA 94101 (as set forth in Section 227).

F. All violations of Section 1777.5 shall pay a civil penalty of Fifty Dollars ($50.00) for each calendar day of noncompliance.

All willful violations of Section 1777.5 shall pay the $50.00 fine for each calendar day of noncompliance and shall be denied the right to bid on, or to receive, any public works contract for a period of up to one year for the first violation and up to three years for any additional violations.

Compliance disputes arising under Section 177.5 shall be adjudicated under 8 California Code of Regulations, Article 1.

G. Within five (5) days of a public works contract award, the awarding agency must send a copy of the award to the Division of Apprenticeship Standards under Section 1773.3.

Within five (5) days of finding any discrepancy regarding the hourly ratio of apprentices to journeymen, the awarding agency shall notify the Division of Apprenticeship Standards.

H. The Contractor shall be responsible for compliance for all apprentice able occupations within these sections.
7-1.01A(6) WORKERS' COMPENSATION

Pursuant to the requirements in Section 1860 of the Labor Code, the Contractor will be required to secure the payment of workers' compensation to the Contractor's employees in conformance with the requirements in Section 3700 of the Labor Code.

37 | P a g e

Prior to the commencement of work, the Contractor shall sign and file with the Engineer a certification in the following form:

"I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers' compensation or to undertake self -insurance in accordance with the provisions of that code, and I will comply with suc h provisions before commencing the performance of the work of this Contract."

This certification is incorporated in the Contract by reference, and signature and return of the Contract as provided in Section 3-1.03, "Execution of Contract," shall constitute signing and filing of the certificate. 7-1.01A(7) SUITS TO RECOVER PENALTIES AND FORFEITURES

Attention is directed to Sections 1730 to 1733, inclusive, of the Labor Code concerning suits to recover amounts withheld from payment for failure to comply with requirements of the Labor Code or Contract provisions based on those laws.

Those sections provide that a suit on the Contract for alleged breach thereof in not making the payment is the exclusive remedy of the Contractor or the Contractor's assignees with reference to amounts withheld for those penalties or forfeitures; and that the suit must be commenced and actual notice thereof received by the awarding authority prior to 90 days after completion of the Contract and the formal acceptance of the job. 7-1.01B FAIR LABOR STANDARDS ACT

The attention of Bidders is invited to the fact that the City of Vallejo has been advised by the Wage and Hour Division, U.S. Department of Labor, that Contractors engaged in highway construction work are required to meet the provisions of the Fair Labor Standards Act of 1938 and as amended (52 Stat. 1060). 7-1.01C CONTRACTOR'S LICENSING LAWS

Attention is directed to the provisions of Chapter 9 of Division 3 of the Business and Professions Code concerning the licensing of Contractors. Contractor shall be properly licensed at all times during the performance of the work and performance of the Contract.

All Bidders and Contractors shall be licensed in accordance with the laws of this State and any Bidder or Contractor not so licensed is subject to the penalties imposed by those laws.

Attention is also directed to the requirements in Public Contract Code Section 10164. In all projects where Federal funds are involved, the Contractor shall be properly licensed at the time the Contract is awarded.

38 | P a g e

7-1.01D VEHICLE CODE

Pursuant to the authority contained in Vehicle Code Section 591, the City of Vallejo has determined that within those areas that are within the limits of the project and are open to public traffic, the Contractor shall comply with all the requirements set forth in Divisions 11, 12, 13, 14 and 15 of the Vehicle Code.

Attention is directed to the statement in Vehicle Code Section 591 that this section shall not relieve the Contractor or any person from the duty of exercising due care. The Contractor shall take all necessary precautions for safe operation of the Contrac tor's equipment and the protection of the public from injury and damage from the Contractor's equipment.
7-1.01E TRENCH SAFETY

Attention is directed to the requirements in Section 6705 of the Labor Code concerning trench excavation safety plans.

The Contractor is warned that when the work involves existing sewers and appurtenances that have been exposed to sewage and industrial wastes, these facilities shall be considered contaminated with disease - causing organisms. Personnel in contact with cont aminated facilities, debris, waste water, or similar items shall be advised by the Contractor of the necessary precautions that must be taken to avoid becoming diseased. It is the Contractor's responsibility to urge his/her personnel to observe a strict r egimen of proper hygienic precautions, including any inoculations recommended by the local public health officer.

Because of the potential danger of solvents, gasoline, and other hazardous material in the existing sewers and storm drain pipes, these areas shall be considered hazardous. The Contractor shall be aware of these dangers and shall comply with Article 108, "Confined Spaces," of the General Industrial Safety Orders contained in Title 8 of the California Administrative Code.

In the event that this Contract requires the excavation of any trench or trenches in excess of five feet in depth, Contractor shall prepare a detailed design plan showing the design of shoring, bracing, sloping, or other provisions to be made for worker pr otection from the hazard of caving ground during the excavation of such trenches. Said detailed design plan and subsequent excavating operations shall fully comply with all local, state and federal regulations including, but not limited to, the Constructi on Safety Orders, Section 1539, Permits and Section 1540 et seq., Excavation.
7-1.01F AIR POLLUTION CONTROL

The Contractor shall comply with all air pollution control rules, regulations, ordinances and statutes which apply to any work performed pursuant to the Contract, including any air pollution control rules, regulations, ordinances and statutes, specified in Section 11017 of the Government Code.

Unless otherwise provided in the special provisions, material to be disposed of shall not be burned, either inside or outside the highway right of way.

39 | P a g e

7-1.01G WATER POLLUTION CONTROL
7-1.01G(1) GENERAL

The intent of these requirements is to enforce federal, state, and other local agency regulation prohibiting storm water pollution from construction sites. The storm drain system discharges directly to creeks and the San Francisco Bay without treatment. Therefore, pollutant discharge into the storm drain system is strictly prohibited. Here pollutant discharge means any substance, material, or waste, and discharges NOT permitted under the National Pollutant Discharge Elimination System (NPDES) regulated b y the State of California Regional Water Quality Control Board (RWQCB) or the United States Environmental Protection Agency (EPA) other than uncontaminated stormwater.

The Contractor shall conform to all applicable local, state, and Federal regulations and laws pertaining to water pollution control. As applicable, the Contractor shall obtain Water Pollution Control Permits and file all documents including, but not limit ed to, the State of California Construction General Permit, Stormwater Pollution Prevention Plan. The Contractor shall conduct and schedule operations and follow and implement Best Management Practices (BMPs) in such a manner as to prevent water pollution. The Contractor shall also conform to the following requirements:

1) Sediments shall not be discharged to a storm drain system or receiving waters. In this subsection, the term "storm drain system" shall include storm water conduits, storm drain inlets and other storm drain structures, street gutters and paved surfaces. In this subsection “receiving waters” shall include channels, watercourses, creeks, lakes, the Mare Island Strait, the Carquinez Strait, and the San Francisco Bay.

2) Sediments generated on the Work site shall be contained within the Work site using appropriate BMPs.

3) No construction-related materials, waste, spill, or residue shall be discharged from the Work site to streets, drainage facilities, receiving waters or adjacent property by wind or runoff.

4) Non-storm water runoff from equipment, vehicle washing, or any other activity shall be contained within the Work site using appropriate BMPs.

5) Erosion shall be prevented. Erosion -susceptible slopes shall be covered, planted, or otherwise protected in a way that prevents discharge from the Work site.

In this subsection, the term “storm drain system” shall include water conduits, storm drain inlets and other storm drain structures, street gutters and paved surfaces, channels, watercourses, creek, lakes, the estuary, and the San Francisco Bay.

The Engineer will notify the Contractor of the acceptance or rejection of any submitted or revised water pollution control program.

The City of Vallejo will not be liable to the Contractor for failure to accept all or any portion of an originally submitted or revised water pollution control program, nor for any delays to the work due to the Contractor's failure to submit an acceptable water pollution control program.

Nothing in the terms of the Contract Documents nor in the provisions in this Section 7 1.01G Water Pollution Control shall relieve the Contractor of the responsibility for compliance with Sections 5650 and 12015 of the Fish and Game Code, or other applicable statutes relating to prevention or abatement of water pollution. 7-1.01G(2) BEST MANAGEMENT PRACTICES (BMP)

For the purpose of eliminating stormwater pollution, the Contractor shall implement effective control measures known as Best Management Practices (BMPs). BMPs include schedules of activities, prohibition of practices,

40 | P a g e

general good housekeeping practices, operational practices, pollution prevention practices, maintenance procedures, and other management procedures to prevent pollutant discharge directly or directly into the storm drain system. BMPs also include the cons truction of some facilities that may be required to prevent, control, and abate stormwater pollution.

The Contractor shall implement and maintain such BMPs as are relevant to the work, and as are specifically required by the project drawings or Specifications. The Contractor shall be responsible throughout the Contract duration for installing, constructing, inspecting, maintaining, removing and disposing of BMPs for wind erosion control, tracking control, erosion and sediment control, non -storm water control, and waste management and materials pollution control. Unless otherwise directed by the Engineer, the Contractor shall be responsible for BMP implementation and maintenance throughout any temporary suspension of the Work. Guidance for appropriate implementation of BMPs can be found in the 7-1.01G(5) Reference Publications, below. 7-1.01G(3) STORM WATER POLLUTION PREVENTION PLAN (SWPPP)

When so specified in the Specifications, or if required by a jurisdictional regulatory agency, the Contractor shall prepare and submit a Storm Water Pollution Prevention Plan (SWPPP). The SWPPP shall conform to the requirements specified in the Specificat ions and those of the jurisdictional regulatory agency. The Notice of Intent will be filed by the City.
7-1.01G(4) DEWATERING

Dewatering shall be performed by the Contractor when specifically required by the project drawings or Specifications, and as necessary for construction of the Work. Dewatering shall be performed in conformance with all applicable local, state and Federal laws and permits issued by jurisdictional regulatory agencies.

Permits necessary for treatment and disposal of accumulated water shall be obtained by the Contractor or the Agency as specified in the Special Provisions. Accumulated water shall be treated prior to disposal if so specified in the Specifications or required by a permit. The contractor shall submit a working drawing and related supporting information detailing its proposed plan and methodology and treatment and disposal of accumulated water. To the maximum extent practical, the Contractor shall reuse non-toxic, de-silted water for other onsite needs, such as dust control and irrigation.

The plan shall identify the location, type and size of dewatering devices and related equipment, the size and type of materials composing the collection system, the size and type of equipment to be used to retain and, if required, treat accumulated water, and the proposed disposal locations. If the proposed disposal location is a sanitary sewer, the Contractor shall submit to the Engineer written evidence of permission from the owner. If the proposed disposal location is a storm drain system or receiving body of water, the Contractor shall submit written evidence of permission from the owner of the storm drain system and, if not obtained by the City, original signed permits from jurisdictional regulatory agencies or written evidence that such permits are n ot required.
7-1.01G(5) REFERENCE PUBLICATIONS

Reference publications are as follows:

1. California State Water Resources Control Board (SWRCB) Construction General Permit Order 2009 - 009-DWQ adopted on September 2, 2009. Available at: the following website:
http://www.swrcb.ca.gov/board_decisions/adopted_orders/water_quality/2012/wqo2012_0006_dwq. pdf

2. California Stormwater Quality Association (CASQA) Stormwater Best Management Practice Handbook. Available at: the following website:
www.casqa.org/resources/bmp-handbooks/construction

3. Erosion and Sediment Control Field Manual, San Francisco Regional Water Quality Control Board

41 | P a g e

(SFRWQCB) Available from Friends of the San Francisco Estuary, 1515 Clay Street, Suite 1400, Oakland, CA 94612 (510) 622-2419 or (510) 622-2337. Available at: the following website:
www.abag.ca.gov/abag/overview/pub/erosion.html

4. Manual of Standards for Erosion and Sediment Control Measures. Association of Bay Area Governments (ABAG.) Available from ABAG, 101 8th Street, Oakland, CA 94607, (510) 464 -7900.

Available at: the following website:
www.abag.ca.gov/abag/overview/pub/erosion.html

5. CalTrans Stormwater Quality Handbooks. Available at: the following website:
www.dot.ca.gov/hq/construc/stormwater/CSBMPM_303_Final.pdf 7-1.01G(6) MATERIAL STORAGE

Storage and exposure of raw materials, by -products, finished products, and containers shall be controlled as described below:

1. All construction materials shall be stored at least ten feet away from inlets, catch basins, and curb returns. The Contractor shall not allow any material to enter the storm drain system. Measures shall be taken to maintain a neat and protected pile. At the end of each working day, the Contractor shall collect and dispose of all scrap, debris, and waste material excluding materials set aside for recycling and salvage. Materials set aside for recycling and salvage shall be delivered to the recycling stat ion within five days.

2. Materials that can contaminate rainwater or be transported by storm water or other runoff to the storm drain system require special storage. During wet weather or when rain is forecast, the Contractor shall store such materials inside a building or cover them with a tarp or other waterproof material secured with weighted tires or sandbags to prevent contact with rain.

3. The Contractor is reminded that storage and disposal of all hazardous materials such as paints, thinners, solvents, and fuels; and all hazardous wastes such as waste oil, must meet all federal, state and local standards and requirements.
7-1.01G(7) PAVEMENT SAW CUTTING OPERATIONS

The Contractor shall prevent any saw cutting debris from entering the storm drain system. The Contractor shall preferably use dry cutting techniques and sweep up residue. If wet methods are used, the Contractor shall vacuum slurry as cutting proceeds or collect all wastewater by constructing a sandbag sediment barrier.

The bermed area shall be of adequate size to collect all wastewater and solids. The Contractor shall allow collected water to evaporate, as approved by the Engineer, if the wastewater vol ume is minimal and if maintaining the ponding area does not interfere with public use of the street area, create a safety hazard, or does not create standing water that remains longer than 72 hours. If the Engineer approves, the Contractor may direct or p ump saw cutting wastewater to a dirt area for infiltration. This dirt area shall be adequate to contain all the wastewater. After wastewater has infiltrated, all remaining saw cutting residue must be removed and disposed of properly.

With the approval of Vallejo Flood and Wastewater District (VFWD) and the Engineer, de-silted water may be pumped to the sanitary sewer to assist in the evaporation or infiltration process. Remaining silt and debris from the ponding or bermed area shall be removed or vacuumed and disposed of properly. If a suitable d irt area is not available or discharge to the sanitary sewer is not feasible, with the Engineer’s approval the Contractor shall filter the saw -cutting wastewater through filtering materials and methods meeting ABAG Standards for Erosion and Sedimentation Control Measures (latest edition) before discharging this wastewater to the storm drain.

42 | P a g e

7-1.01G(8) PAVEMENT OPERATIONS

The Contractor shall prevent the discharge of pollutants from paving operations by using measures to prevent run-on and runoff pollution, properly disposing of wastes, and by implementing the following Best Management Practices:

a. No paving during wet weather.

b. Store materials as required by 7-1.01G(6) Material Storage.

c. Cover inlets and manholes when applying asphalt, seal coat, tack coat, slurry seal, fog seal, etc.

d. Place drip pans or absorbent materials under paving equipment when not in use. During wet weatherstore contaminated paving equipment indoors or cover with tarp or other waterproof covering.

e. Sweep work site daily to prevent sand, gravel or excess asphalt from entering, or being transported by rain, into the storm drain system.

f. Keep ample supplies of drip pans or absorbent materials on-site.

g. If paving involves Portland cement concrete, refer to 7-1.01G(6) Material Storage. 7-1.01G(9) CONCRETE OPERATIONS

The Contractor shall prevent pollutant discharge from concrete operations by using measures to prevent run - on and runoff pollution, by properly disposing of wastes, and by implementing the following BMPs:

a. Store all materials in waterproof containers or under cover away from drain inlets or drainage areas.

b. Avoid mixing excess amounts of Portland cement materials.

c. Do not wash out concrete trucks into storm drains, open ditches, streets, streams etc. Whenever possible, perform washout of concrete trucks off site where discharge is controlled and not permitted to discharge to the storm drain system.

For on-site washout:

i. Locate washout area at least 50 feet from storm drains, open ditches or other water bodies, preferably in a dirt area. Prevent runoff from this area by constructing a temporary pit or bermed area large enough to store the liquid and solid waste.

ii. Wash out concrete wastes into the temporary pit where the concrete can set, be broken up and then disposed of properly. If the water volume greater than what will allow concrete to set, allow the wash water to infiltrate and/or evaporate, if possible. Ot herwise, allow wash water to settle, then filter and pump it to the sanitary sewer with approval from VSFCD and the Engineer. Remove or vacuum the remaining silt and debris from the ponding or bermed area and dispose of it properly.

d. Dispose of wastewater from exposed aggregate washing to a dirt area adequate to contain all the wastewater. Once the wastewater has infiltrated, remove any remaining residue. If a suitable dirt area is not available, filter the wash water through straw bal es or other filtering materials meeting ABAG Standards for Erosion and Sediment Control Measures before discharging the wash water to the sanitary sewer with approval from VSFCD and the Engineer.

e. Collect and return sweepings from exposed aggregate concrete to a stockpile or dispose of the waste in a trash container.

43 | P a g e

7-1.01G(10) GRADING AND EXCAVATION OPERATIONS

The Contractor shall implement sedimentation and erosion control measures to prevent sediments or excavated material from entering the storm drain system.

The erosion and sedimentation control materials and methods shall be in accordance with ABAG Standards for Erosion and Sediment Control Measures and/or the procedures and methods described in the SFRWQCB Erosion and Sediment Control Field Manual.

At a minimum, the Contractor shall install filter materials (such as sandbags, filter fabric, etc.) at storm drain inlet(s) located in and downstream of the project site. These materials must be in place between October 15 and April 15 and also when rain is forecast within 24 hours. The Contractor shall install filter materials or seal all surface inlet openings during the dry season or if there is potential for sediment or excavated material to be discharged to the storm drain system during the construction operation (e.g. sediments and debris tracked by construction vehicles, wind-blown or transported by other runoff). The storm drain inlets shall be sealed such that they can be opened in an emergency and unblocked at the end of each working day, so that no property is damaged as a result of accidents or overflows.

Apply permanent erosion control materials within 24 hours after completion of final ground preparation unless prohibited by unsuitable weather conditions, including precipitation, saturated soil conditions, or excessive wind, as determined by the Engineer.

When adverse weather conditions prevent installation within the 24 -hour period, implement temporary stabilization measures immediately upon completion of grading and maintain such measures until permanent erosion control materials can be applied. Temporary stabilization measures may include plastic sheeting, fiber rolls, bonded fiber matrix, straw mulch, soil stabilizers, temporary cover, or other approved BMPs. Install permanent erosion control materials as soon as weather and site conditions become suitable and in accordance with manufacturer recommendations and the Engineer’s direction.

Sedimentation and erosion control/filter materials shall be placed in a manner to restrain any debris or sediment from flowing into the storm drain system. Said materials or control devices shall also be maintained and/or replaced as necessary to ensure effective sediment control and to prevent flooding. 7-1.01G(11) SPILL PREVENTION AND CONTROL

The Contractor shall take all precautions to prevent accidental spills during construction. However, in the event of a spill, the Contractor shall immediately contain any leaks/spills to prevent them from entering the storm drain system. The Contractor s hall properly clean up and dispose of spilled wastes and resulting clean -up materials. If the spilled waste is hazardous, the Contractor shall comply with all federal, state and local hazardous waste requirements.

a. The Contractor shall not wash any spilled material into the streets, gutters, storm drains, or creeks.

b. The Contractor shall report any hazardous materials spill immediately to the Vallejo Fire Department, the Solano County Department of Resource Management Environmental Services Division Hazardous Materials Section and other state and local agencies as required by state and local regulations. 7-1.01G(12) VEHICLE/EQUIPMENT CLEANING

The use of soaps, solvents, de -greasers, steam cleaning equipment or equivalent methods for vehicle or equipment cleaning on-site or in the street is not permitted. Vehicle or equipment may be cleaned only with water in a designated, bermed area of adequa te size. Rinse water may not runoff site or into the storm drain system. The rinse-water shall be permitted to infiltrate in dirt area or shall be discharged to the sanitary sewer with the approval of VFWD and the Engineer.

44 | P a g e

The Contractor shall dispose of wash water from the cleaning of water-based paint equipment and tools to the sanitary sewer.

When using oil-based paint the Contractor shall, to the maximum extent practicable, filter the paint thinner and solvents for reuse. Any waste thinner, solvent, and sludge from the cleaning of equipment and tools shall be disposed as hazardous waste.
7-1.01G(13) CONTRACTOR TRAINING AND AWARENESS

The Contractor shall train all employees on the water pollution prevention requirements contained in these specifications. The Contractor shall inform all subcontractors of the water pollution prevention contract requirements and include appropriate subcontract provisions to ensure that these requirements are met.

The Contractor shall mark all new catch basins constructed as part of the project with storm drain markers with the logo "No Dumping: Drains to the Bay". Storm drain markers shall be approved by the City Engineer. 7-1.01G(14) GOOD HOUSEKEEPING PRACTICES

The Contractor shall implement the following applicable good housekeeping practices.

a. Store all materials that have the potential to be transported to the storm drain system by storm runoff or by a spill under cover in a contained area or in sealed waterproof containers.

b. Use ground tarps to collect fallen debris or splatters that could contribute to storm water pollution.

c. Secure opened bags of cement, and other light materials or powders that can be transported by wind.

d. Pick up litter, construction debris and other wastes daily from outside areas including the sidewalk area, gutter, street pavement and storm drains impacted by the project. Store all wastes in covered containers or dispose of immediately. Arrange for appr opriate collection of those materials separated for recycling.

e. Dispose of wash water to the sanitary sewer with the approval of VSFCD and the Engineer or recycle wash water. Refer to 7-1.01G(9) Concrete Operations.

f. Inspect vehicles and equipment arriving on-site for leaking fluids and promptly repair leaking vehicles and equipment. Use drip pans to catch leaks until repairs are made.

g. Avoid spills by handling materials carefully. Keep a stockpile of spill materials, such as rags or absorbents, readily accessible on -site. Clean up all spills immediately to prevent any material from being discharged to the storm drain system. Refer to 7-1.01G(11) Spill Prevention and Control.

h. Train employees regularly on good housekeeping practices and BMPs. Assign specific employees responsibility for BMPs, good housekeeping practices, and actions to take in the event of a spill. Refer to 7-1.01G(13) Contractor Training and Awareness.

i. Maintain and replace all sediment and water pollution control devices as necessary to ensure that said controls are working effectively (e.g. inspect all sediment ponds or sandbag sedimentation/filtering systems after each rain. Remove accumulated sediment and debris and replace or repair damaged sandbags immediately.)

7-1.01G(15) PAYMENT

Unless otherwise specified in the Specifications, payment for implementation and maintenance of BMPs,

45 | P a g e

implementing SWPPP measures and other work of this section (including dewatering) shall be deemed included in the price paid for associated contract bid items, and no additional payment shall be made therefor. 7-1.01G(16) ENFORCEMENT

Various sections of the Vallejo Municipal Code12.41 enforce section 7.101G. City enforcement may include, but is not limited to: citations, abatement orders, bills for City cleanup costs and administration, civil suits, and criminal charges. City enforcement actions do not void or suspend any enforcement actions by other agencies.

At a minimum, the Contractor shall implement the storm water Clean Water Program BMPs listed in 7-1.01G(1) General, or implement equally effective alternatives approved by the Engineer on all projects within the City of Vallejo.
7-1.01H USE OF PESTICIDES

The Contractor shall comply with all rules and regulations of the Department of Food and Agriculture, the Department of Health, the Department of Industrial Relations, City of Vallejo Standard Specifications and all other agencies which govern the use of pesticides required in the performance of the work on the Contract.

Pesticides shall include but shall not be limited to herbicides, insecticides, fungicides, rodenticides, germicides, nematocides, bactericides, inhibitors, fumigants, defoliants, desiccants, soil sterilants and repellents.

Any substance or mixture of substances intended for preventing, repelling, mitigating, or destroying weeds, insects, diseases, rodents, or nematodes and any substance or mixture of substances intended for use as a plant regulator, defoliant or desiccant shall be considered a pesticide. 7-1.01I SOUND CONTROL REQUIREMENTS

The Contractor shall comply with all local sound control and noise level rules, regulations and ordinances which apply to any work performed pursuant to the Contract.

Each internal combustion engine, used for any purpose on the job or related to the job, shall be equipped with a muffler of a type recommended by the manufacturer. No internal combustion engine shall be operated on the project without the muffler.

The noise level from the Contractor's operations, between the hours of 9:00 p.m. and 7:00 a.m. shall not exceed 50 dBA and between the hours of 7:00 a.m. and 9:00 p.m. shall not exceed 80 dBA at a distance of 50 feet.

Said noise level requirement shall apply to all equipment on the job or related to the job, including but not limited to trucks, transit mixers or transient equipment that may or may not be owned by the Contractor. The use of loud sound signals shall be a voided in favor of light warnings except those required by safety laws for the protection of personnel.

Full compensation for conforming to the requirements of this section shall be considered as included in the prices paid for the various contract items of work involved and no additional compensation will be allowed therefor.
7-1.01J ASSIGNMENT OF ANTITRUST ACTIONS

The Contractor's attention is directed to the following requirements in Public Contract Code 7103.5 and Government Code Sections 4553 and 4554, which shall be applicable to the Contractor and the Contractor's subcontractors:

"In entering into a public works Contract or a subcontract to supply goods, services, or materials pursuant to a

46 | P a g e

public works Contract, the Contractor or subcontractor offers and agrees to assign to the awarding body all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C.

Sec. 15) or under the Cartwrigh t Act (Chapter 2 (commencing with Section 16700) of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services, or materials pursuant to the public works Contract or the subcontract. This assignment shall be made and become effective at the time the awarding body tenders final payment to the Contractor, without further acknowledgment by the parties.

If an awarding body or public purchasing body receives, either through judgment or settlement, a monetary recovery for a cause of action assigned under this chapter, the assignor shall be entitled to receive reimbursement for actual legal costs incurred and may, upon demand, recover from the public body any portion of the recovery, including treble damages, attributable to overcharges that were paid by the assignor but were not paid by the public body as part of the bid price, less the expenses incurred in obtaining that portion of the recovery.

Upon demand in writing by the assignor, the assignee shall, within one year from such demand, reassign the cause of action assigned under this part if the assignor has been or may have been injured by the violation of law for which the cause of action arose and (a) the assignee has not been injured thereby, or (b) the assignee declines to file a court action for the cause of action." 7-1.02 LOAD LIMITATIONS

Unless expressly permitted in the special provisions, construction equipment or vehicles of any kind which, laden or unladen, exceed the maximum weight limitations set forth in Division 15 of the Vehicle Code, shall not be operated over completed or existi ng treated bases, surfacing, pavement or structures in any areas within the limits of the project, whether or not the area is subject to weight limitations under Section 7-1.01D, "Vehicle Code," except as hereinafter provided in this Section 7-1.02.

After application of the curing seal, no traffic or Contractor's equipment will be permitted on cement treated base or lean concrete base for a period of 72 hours. After 72 hours, traffic and equipment operated on the base shall be limited to that used in paving operations and placing additional layers of cement treated base.

No traffic or Contractor's equipment will be permitted on treated permeable base except for that equipment required to place the permeable base and the subsequent layer of pavement. Trucks used to haul treated base, Portland cement concrete, or asphalt concrete shall enter onto the base to dump at the nearest practical entry point ahead of spreading equipment. Empty haul trucks shall exit from the base at the nearest practical exit point. Entry and exit points shall not be more than 300 m {1,000 feet} ahead of spreading equipment except in locations where Specifications prohibit operation of trucks outside the area occupied by the base or where steep slopes or other conditions preclude safe operation of hauling equipment. In those locations, entry and exit points shall be established at the nearest point ahead of spreading equipment permitted by Specifications and allowing safe operation of hauling equipment. Damage to curing seal or base shall be repaired promptly by the Contractor, at the Contractor's expense, as directed by the Engineer.

Within the limits of the project and subject to the control of the Engineer, and provided that the Contractor, at the Contractor's expense, shall provide such protective measures as are deemed necessary by the Engineer and shall repair any damage caused by the operations, the Contractor will be permitted to:

Make transverse crossings of those portions of an existing public road or street that are within the highway right of way, with construction equipment which exceeds the size or weight limitations set forth in Division 15 of the Vehicle Code.

Make transverse crossings of treated bases, surfacing or pavement which are under construction or which have been completed, with construction equipment which exceeds the size or weight limitations set forth in Division 15 of the Vehicle Code.

Cross bridge structures that are not open to public traffic and which are designed for HS20 -44 Live Loading (culverts and pipes excluded), with construction equipment which exceeds the size or weight limitations set forth in Division 15 of the Vehicle Code , but not exceeding the load limitations hereinafter specified, provided

47 | P a g e

that the Contractor furnishes to the Engineer the dimensions and maximum axle loadings of equipment proposed for use on bridge structures:

The maximum loading on bridge structures due to pneumatic-tired truck and trailer combinations shall not exceed (1) 12,700 kg {28,000 pounds} for single axles, (2) 21,700 kg {48,000 pounds} for tandem axles, nor (3) 27,200 kg {60,000 pounds} total gross lo ad for single vehicles or 50,000 kg {110,000 pounds} total gross load for truck and trailer or semi-trailer combinations.

The loading on bridge structures due to 2 and 3 axle pneumatic-tired earthmovers shall not exceed that shown in the following table.

Allowable Construction Loading On Bridges
For 2 and 3 Axle Earthmovers
Spacing of Bridge Girders (center to center in
meters {feet})
Maximum Axle Loading (in kilograms {pounds})

1.2 {4} 12,700 {28,000}

1.5 {5} 13,100 {29,000}

1.8 {6} 13,600 {30,000}

2.1 {7} 14,500 {32,000}

2.4 {8} 15,400 {34,000}

2.7 {9} 16,700 {37,000}

3.0 {10} and over 18,000 {40,000}
Minimum axle spacing:

For 3-axle earthmovers
Axles 1 to 2 = 2.4 m {8 feet}
Axles 2 to 3 = 6.1 m {20 feet}
For 2-axle earthmovers
Axles 1 to 2 = 6.1 m {20 feet}

Move equipment within the limits of the project over completed or existing base, surfacing, pavement and structures, whether or not open to the public, in accordance with the limitations and conditions in the "Permit Policy" of the City of Vallejo of Transportation.

Within the limits of the project and subject to the condition that the Contractor shall repair, at the Contractor's expense, any damage caused thereby, the Contractor will be permitted to cross culverts and pipes with construction equipment which exceeds the size or weight limitations set forth in Division 15 of the Vehicle Code in accordance with the conditions set forth on the drawings. If the conditions are not set forth on the drawings, the provisions in the first paragraph in this Section 7-1.02 will apply.

Should the Contractor desire to increase the load carrying capacity of a structure or structures which are to be constructed as a part of the Contract, in order to facilitate the Contractor's own operations, the Contractor may request the Engineer to consi der redesigning the structure or structures. Proposals by the Contractor to increase the load carrying capacity of structures above 59 000 kg {130,000 pounds} per single axle or pair of axles less than 2.4 m {8 feet} apart, or above 149 000 kg {330,000 pounds} total gross vehicle weight, will not be approved. The request shall include a description of the structure or structures involved and a detailed description of the overloads to be carried, the date the revised drawings would be required, and a state ment that the Contractor agrees to pay all costs involved in the strengthening of the structure or structures, including the cost of revised drawings, and further that the Contractor agrees that no extension of time will be allowed by reason of any delay t o the work which may be due to the alteration of the structure or structures. If the Engineer determines that strengthening the structure or structures will be permitted, the Engineer will inform the Contractor of the estimated cost of the alterations, in cluding engineering, and the date that revised drawings could be furnished. If the cost and date are satisfactory to the Contractor, the Engineer will prepare a change order providing for the agreed upon alterations.

Pursuant to the authority contained in Section 591 of the Vehicle Code, the Department has determined that, within such areas as are within the limits of the project and are open to public traffic, the Contractor shall

48 | P a g e

comply with all of the requirements set forth in Divisions 11, 12, 13, 14, and 15 of the Vehicle Code. Attention is directed to the statements in Section 591 that this section shall not relieve him or any person from the duty of exercising due care. The Contractor shall take all necessary precautions for safe operation of his/her equipment and the protection of the public from injury and damage from such equipment. 7-1.03 PAYMENT OF TAXES

The Contract prices paid for the work shall include full compensation for all taxes which the Contractor is required to pay, whether imposed by Federal, State or local government, including, without being limited to, Federal excise tax. No tax exemption c ertificate or any document designed to exempt the Contractor from payment of any tax will be furnished to the Contractor by the City of Vallejo, as to any tax on labor, services, materials, transportation, or any other items furnished pursuant to the Contract. 7-1.04 PERMITS AND LICENSES

The City will waive all required City of Vallejo permit fees for this project.

The Contractor and all subcontractors shall obtain and keep current for the duration of the project a City of Vallejo business license.

The Contractor shall give all notices required by and comply with all laws, codes, ordinances and regulations.

Before installing any work, the Contractor shall carefully examine the Contract Documents for compliance with all laws, codes, ordinances and regulations and shall immediately report any discrepancy to the Engineer.

Should the Contractor proceed with the construction and/or install any utility variance, notwithstanding the fact that such installation is in compliance with the Contract Documents, or should the Contractor install any work not in compliance with all laws , codes, ordinances and regulations, the Contractor shall remove such work without cost to the City of Vallejo.

The Contractor shall commit no trespass on any public or private property in any operation due to or connected with the improvements embraced in this contract.

The Environmental Quality Act (Public Resources Code, Sections 21000 to 21176, inclusive) may be applicable to permits, licenses and other authorizations which the Contractor must obtain from local agencies in connection with performing the work of the Con tract. The Contractor shall comply with the provisions of those statutes in obtaining the permits, licenses and other authorizations and they shall be obtained in sufficient time to prevent delays to the work.

In the event that the City of Vallejo has obtained permits, licenses or other authorizations, applicable to the work, in conformance with the requirements in the Environmental Quality Act or any other authority, the Contractor shall comply with the provisions of those permits, licenses and other authorizations. 7-1.05 PATENTS

The Contractor shall assume all costs arising from the use of patented materials, equipment, devices or processes used on or incorporated in the work, and agrees to indemnify and save harmless the City of Vallejo, the Director, the Engineer, and their duly authorized representatives, from all suits at law, or actions of every nature for, or on account of the use of any patented materials, equipment, devices or processes.

7-1.06 SAFETY AND HEALTH PROVISIONS

The Contractor shall conform to all applicable occupational safety and health standards, rules, regulations and orders established by the State of California.

49 | P a g e

Working areas utilized by the Contractor to perform work during the hours of darkness, shall be lighted to conform to the minimum illumination intensities established by California Division of Occupational Safety and Health Construction Safety Orders.

All lighting fixtures shall be mounted and directed in a manner precluding glare to approaching traffic.

Full compensation for conforming to the provisions in this section shall be considered as included in the Contract prices paid for the various items of work involved and no separate payment will be made therefor. 7-1.07 (BLANK)
7-1.08 PUBLIC CONVENIENCE

This Section 7-1.08 defines the Contractor's responsibility with regard to convenience of the public and public traffic in connection with the Contractor's operations.

Attention is directed to Section 7-1.09, "Public Safety," for provisions relating to the Contractor's responsibility for the safety of the public. The provisions in Section 7-1.09 are in addition to the provisions in this Section 7-

1.08, and the Contractor will not be relieved of the responsibilities as set forth in Section 7 -1.09 by reason of conformance with any of the provisions in this Section 7-1.08.

Attention is directed to Section 12, "Construction Area Traffic Control Devices," for provisions concerning flagging and traffic-handling equipment and devices used in carrying out the provisions in this Section 7 -1.08 and Section 7-1.09.

In the event of a suspension of the work, attention is directed to Section 8 -1.05, "Temporary Suspension of Work."

The Contractor shall so conduct operations as to offer the least possible obstruction and inconvenience to the public and shall have under construction no greater length or amount of work than can be prosecuted properly with due regard to the rights of the public.

Unless otherwise provided in the special provisions, all public traffic shall be permitted to pass through the work with as little inconvenience and delay as possible. Where possible, public traffic shall be routed on new or existing paved surfaces.

Spillage resulting from hauling operations along or across any public traveled way shall be removed immediately by the Contractor at the Contractor's expense.

Existing traffic signals and highway lighting shall be kept in operation for the benefit of the traveling public during progress of the work, and other forces will continue routine maintenance of existing systems.

Construction operations shall be conducted in such a manner as to cause as little inconvenience as possible to abutting property owners.

Convenient access to driveways, houses, and buildings along the line of the work shall be maintained and temporary approaches to crossings or intersecting highways shall be provided and kept in good condition.

When the abutting property owner's access acr oss the right of way line is to be eliminated, or to be replaced under the Contract by other access facilities, the existing access shall not be closed until the replacement access facilities are usable.

The Contractor may be required to cover certain signs which regulate or direct public traffic to roadways that are not open to traffic. The Engineer will determine which signs shall be covered. Except as otherwise provided for construction area signs in Section 12, "Construction Area Traffic Control Devices," furnishing, installing and removing covers will be paid for as extra work as provided in Section 4 -1.03D.

50 | P a g e

Roadway excavation and the construction of embankments shall be conducted in such a manner as to provide a reasonably smooth and even surface satisfactory for use by public traffic at all times; sufficient fill at culverts and bridges to permit traffic to cross shall be placed in advance of other grading operations; and if ordered by the Engineer roadway cuts shall be excavated in lifts and embankments constructed part width at a time, construction being alternated from one side to the other and traffic routed over the side opposite the one under construction. Culvert installation or culvert construction shall be conducted on but one -half the width of the traveled way at a time, and that portion of the traveled way being used by public traffic shall be kept open and unobstructed until the opposite side of the traveled way is ready for use by traffic.

Upon completion of rough grading at the grading plane, or placing any subsequent layer thereon, the surface of the roadbed shall be brought to a smooth, even condition free of humps and depressions, satisfactory for the use of public traffic.

After the surface of the roadbed has been brought to a smooth and even condition for the passage of public traffic as above provided, any work ordered by the Engineer for the accommodation of public traffic prior to commencing subgrade operations will be paid for as extra work as provided in Section 4-1.03D. After subgrade preparation for a specified layer of material has been completed, the Contractor shall, at the Contractor's expense, repair any damage to the roadbed or completed subgrade, including damage caused by the Contractor's operations or use by public traffic.

While subgrade and paving operations are underway, public traffic shall be permitted to use the shoulders and, if half-width paving methods are used, shall also be permitted to use the side of the roadbed opposite the one under construction. When sufficient width is available, a passageway wide enough to accommodate at least 2 lanes of traffic shall be kept open at locations where subgrade and paving operations are in active progress.

Any shaping of shoulders or reshaping of subgrade necessary for the accommodation of public traffic thereon during subgrade preparation and paving operations will be paid for as extra work a s provided in Section 4-1.03D.

Water or dust palliative shall be applied if ordered by the Engineer for the alleviation or prevention of dust nuisance as provided in Section 10, "Dust Control."

The Contractor will be required to pay the cost of replacing or repairing all facilities installed under extra work for the convenience or direction or warning of public traffic that are lost while in the Contractor's custody, or are damaged by reason of t he Contractor's operations to such an extent as to require replacement or repair, and deductions from any moneys due or to become due the Contractor will be made to cover the cost.

Whenever a section of surfacing, pavement or the deck of a structure has been completed, the Contractor shall open it to use by public traffic if the Engineer so orders or may open it to use by public traffic if the Engineer so consents. In either case th e Contractor will not be allowed any compensation due to any delay, hindrance or inconvenience to the Contractor's operations caused by public traffic, but will thereupon be relieved of responsibility for damage to completed permanent facilities caused by public traffic, within the limits of that use. The Contractor will not be relieved of any other responsibility under the Contract nor will the Contractor be relieved of cleanup and finishing operations.

Except as otherwise provided in this Section 7 -1.08 or in the special provisions, full compensation for conforming to the provisions in this Section 7 -1.08 shall be considered as included in the prices paid for the various Contract items of work and no additional compensation will be allowed therefor.

Contractor shall furnish, install and maintain all traffic warning and directional signs necessary to maintain the facility in a passable condition at all times. Temporary traffic control shall meet the requirements of the latest State of California Department of Transportation Manual of Traffic Controls for Construction and Maintenance Work Zones. The contractor shall submit a Temporary traffic control Plan for review and acceptance by the Engineer at the pre-construction meeting.

The Contractor shall designate in writing the name, address and telephone number of the employee and the superintendent to contact after working hours for the proper maintenance of barriers and signs.

51 | P a g e

Barricades of the flashing beacon variety shall be placed at each excavation site and left until the Engineer deems there is no longer a hazard.

Full compensation for furnishing all flag persons necessary for the direction of public traffic either through or around the work shall be considered as included in the various contract items of work, and no additional compensation will be allowed therefor.
7-1.09 PUBLIC SAFETY

It is the Contractor's responsibility to provide for the safety of traffic and the public during construction.

Attention is directed to Section 7-1.12, "Indemnification and Insurance."

Attention is directed to Section 7 -1.08, "Public Convenience," for provisions relating to the Contractor's responsibility for providing for the convenience of the public in connection with the Contractor's operations.

Attention is directed to Section 12, "Construction Area Traffic Control Devices," for provisions concerning flagging and traffic-handling equipment and devices used in carrying out the provisions of Section 7 -1.08 and this Section 7-1.09.

Whenever the Contractor's operations create a condition hazardous to traffic or to the public, the Contractor shall, at the Contractor's expense and without cost to the City of Vallejo, furnish, erect and maintain those fences, temporary railing (Type K), barricades, lights, signs and other devices and take such other protective measures that are necessary to prevent accidents or damage or injury to the public.

Fences, temporary railing (Type K), barricades, lights, signs, and other devices furnished, erected and maintained by the Contractor, at the Contractor's expense, are in addition to any construction area traffic control devices for which payment is provided for elsewhere in the Contract Documents.

The Contractor shall also furnish such flaggers as are necessary to give adequate warning to traffic or to the public of any dangerous conditions to be encountered, and payment therefor will be made as provided in Section 12-2.02, "Flagging Costs."

Signs, lights, flags, and other warning and safety devices and their use shall conform to the requirements set forth in the current California Manual on Uniform Traffic Controls. Devices or other protective devices furnished and erected by the Contractor, at the Contractor's expense, as above provided, shall not obscure the visibility of, nor conflict in intent, meaning and function of either existing signs, lights and temporary traffic control devices or any construction area signs and temporary traffic control devices for which furnishing of, or payment for, is provided elsewhere in the Specifications. Signs furnished and erected by the Contractor, at the Contractor's expense, shall be approved by the Engineer as to size, wording and location.

The installation of general roadway illumination shall not relieve the Contractor of the responsibility for furnishing and maintaining any of the protective facilities herein before specified.

Construction equipment shall enter and leave the highway via existing ramps and crossovers and shall move in the direction of public traffic. All movements of workmen and construction equipment on or across lanes open to public traffic shall be performed in a manner that will not endanger public traffic.

The Contractor's trucks or other mobile equipment which leave a freeway lane, that is open to public traffic, to enter the construction area, shall slow down gradually in advance of the location of the turnoff to give following public traffic an opportunity to slow down.

When leaving a work area and entering a roadway carrying public traffic, the Contractor's equipment, whether empty or loaded, shall in all cases yield to public traffic.

52 | P a g e

Lanes, ramps and shoulders shall be closed in accordance with the details shown on the drawings, the provisions of Section 12, "Construction Area Traffic Control Devices," and as provided in the special provisions.

The Contractor shall notify the Engineer not less than 15 days before the anticipated start of each falsework and girder erection operation whenever the falsework or girders will reduce clearances available to public traffic.

Pedestrian openings through falsework shall be paved or provided with full width continuous wood walks and shall be kept clear. Pedestrians shall be protected from falling objects and curing water for concrete. Overhead protection for pedestrians shall e xtend not less than 1.2 m {4 feet} beyond the edge of the bridge deck. All pedestrian openings through falsework shall be illuminated in conformance with the provisions in Section 86-6.11, "Falsework Lighting."

Where the height of vehicular openings through falsework is less than 4.6 m {15 feet}, a W34B "Vertical Clearance" sign shall be provided above each opening facing approaching traffic. The signs shall have black letters and numbers on an orange reflectoriz ed background and shall be illuminated so that the signs are clearly visible. The minimum height of the letters and numbers shall be 150 mm {6 inches} and 250 mm {10 inches}, respectively.

No material or equipment shall be stored where it will interfere with the free and safe passage of public traffic, and at the end of each day's work and at other times when construction operations are suspended for any reason, the Contractor shall remove a ll equipment and other obstructions from that portion of the roadway open for use by public traffic.

Temporary facilities which the Contractor uses to perform the work shall not be installed or placed where they will interfere with the free and safe passage of public traffic.

Temporary facilities which could be a hazard to public safety if improperly designed shall comply with design requirements specified in the Contract for those facilities or, if none are specified, with standard design criteria or codes appropriate for the facility involved. Working drawings and design calculations for the temporary facilities shall be prepared and signed by an engineer who is registered as a Civil Engineer in the State of California and shall be submitted to the Engineer for review pursuan t to Section 5 -1.02, "Plans and Working Drawings." The submittals shall designate thereon the standard design criteria or codes used. Installation of the temporary facilities shall not start until the Engineer has reviewed and accepted the drawings.

Should the Contractor appear to be neglectful or negligent in furnishing warning devices and taking protective measures as above provided, the Engineer may direct attention to the existence of a hazard and the necessary warning devices shall be furnished a nd installed and protective measures taken by the Contractor at the Contractor's expense. Should the Engineer point out the inadequacy of warning devices and protective measures, that action on the part of the Engineer shall not relieve the Contractor fro m responsibility for public safety or abrogate the obligation to furnish and pay for these devices and measures.

Provision for the payment for signs, lights, flares, temporary railing (Type K), barricades, and other facilities by extra work as provided in Section 7-1.08, "Public Convenience," or by Contract item as provided in Section 12, "Construction Area Traffic C ontrol Devices," shall in nowise relieve the Contractor from the responsibility as provided in this Section 7-1.09.

Except as otherwise provided in this Section 7 -1.09 or in the special provisions, full compensation for conforming to all of the provisions in this Section 7 -1.09 shall be considered as included in the prices paid for the various Contract items of work and no additional compensation will be allowed therefor.

The Contractor shall note that the work may be performed on or in the vicinity of private property. The Contractor shall, at all times, remove all litter, debris, and construction waste, minimize noise, dust, standing water, vibrations, hazardous conditions and provide safe access to these properties. The Contractor is prohibited from using any and all privately owned utilities. The Contractor's materials and equipment shall not be stored upon private property without written approval from the resident and/or owner.

53 | P a g e

Construction on private property during overtime, weekend, holiday or any other irregular period shall be performed only when the Contractor has requested and received written approval from the adjacent residents and the City Engineer.

No separate payment shall be made for the above considerations. Full compensation for the above construction restrictions shall be considered as included in the price paid for the various items of work involved. 7-1.10 USE OF EXPLOSIVES

Explosives shall not be used.
7-1.11 PRESERVATION OF PROPERTY

Attention is directed to Section 7 -1.12, "Indemnification and Insurance," and to Section 8 -1.10, "Utility and Non-Highway Facilities." Due care shall be exercised to avoid injury to existing highway improvements or facilities, utility facilities, adjacent property, and roadside trees, shrubs and other plants that are not to be removed.

Roadside trees, shrubs and other plants that are not to be removed, and pole lines, fences, signs, markers and monuments, buildings and structures, conduits, pipelines under or above ground, sewer and water lines, all highway facilities and any other impro vements or facilities within or adjacent to the highway shall be protected from injury or damage, and if ordered by the Engineer, the Contractor shall provide and install suitable safeguards, accepted by the Engineer, to protect the objects from injury or damage. If the objects are injured or damaged by reason of the Contractor's operations, the objects shall be replaced or restored at the Contractor's expense. The facilities shall be replaced or restored to a condition as good as when the Contractor entered upon the work, or as good as required by the Specifications accompanying the Contract, if any of the objects are a part of the work being performed under the Contract. The Engineer may make or cause to be made those temporary repairs that are necessary to restore to service any damaged highway facility. The cost of the repairs shall be borne by the Contractor and may be deducted from any moneys due or to become due to the Contractor under the Contract.

Pole lines, fences, signs, markers and monuments, buildings and structures, conduits, pipelines under o r above ground, sewer and water lines, all site facilities and any other improvements or facilities within or adjacent to the site shall be protected from injury or damage, and if ordered by the Engineer, the Contractor shall provide and install suitable saf eguards, accepted by the Engineer, to protect the objects from injury or damage. If the objects are injured or damaged by reason of the Contractor's operations, the objects shall be replaced or restored at the Contractor's expense. The facilities shall be replaced or restored to a condition as good as when the Contractor entered upon the work, or as good as required by the Specifications accompanying the Contract, if any of the objects are a part of the work being performed under the Contract.

The Engineer may make or cause to be made those temporary repairs that are necessary to restore to service any damaged site facility. The cost of the repairs shall be borne by the Contractor and may be deducted from any moneys due or to become due to the Contractor under the Contract.

The fact that any underground facility is not shown upon the drawings shall not relieve the Contractor of the responsibility under Section 8 -1.10, "Utility and Non -Highway Facilities." It shall be the Contractor's responsibility, pursuant thereto, to ascertain the location of those underground improvements or facilities which may be subject to damage by reason of the Contractor's operations.

Any damage to private property caused by the Contractor and adjudged to be the responsibility of the Contractor by the Engineer shall be rectified to the satisfaction of the Engineer within a reasonable time, depending upon the extent of the damage. Said reasonable time shall be as determined by the Engineer, and if the condition is not rectified, the Engineer shall have the power and authority to rectify said damage and the cost thereof to be paid for by the Contractor, either by direct payment to the City of Vallejo, or by deducting said amount from moneys due the Contractor.

Full compensation for furnishing all labor, materials, tools, equipment, and incidentals, and for doing all the work involved in protecting or repairing property as specified in this Section 7 -1.11, shall be considered as

54 | P a g e

included in the prices paid for the various Contract items of work and no additional compensation will be allowed therefor.
7-1.12 INDEMNIFICATION AND INSURANCE

The Contractor's obligations regarding indemnification of the City of Vallejo and the requirements for insurance shall conform to the provisions in Sections 7-1.12A, "Indemnification," and 7-1.12B, "Insurance," of this Section 7-1.12.
7-1.12A INDEMNIFICATION

Contractor shall, to the maximum extend allowed by law, defend, indemnify, and save harmless City of Vallejo (including its inspectors, project managers, trustees, officers, agents, members, employees, affiliates, consultants, subconsultants, and representatives), and each of them, of and from any and all claims, demands, suits, causes of action, damages, costs, expenses, attorneys' fees, losses, or liability, in law or in equity, of every kind and nature whatsoever arising out of, or in connection with, Contractor's operations to be performed under this Contract, including, but not limited to:

A. Personal injury (including, but not limited to, bodily injury, emotional injury or distress, sickness, or disease) or death to persons, including, but not limited to, Contractor, any employees or agents of Contractor, City of Vallejo, or any subcontractor, or damage to property of anyone including the work itself (including loss of use thereof), caused or alleged to be caused in whole or in part by any negligent act or omission of Contractor, its agents, employees, subcontractors or material suppliers, City of Vallejo, or anyone directly or indirectly employed by them, or anyone for whose acts they may be liable;

B. Penalties threatened, sought, or imposed on account of the violation of any law, order, citation, rule, regulation, standard, ordinance, or statute, caused by the action or inaction of Contractor, its agents, employees, subcontractors or material suppliers;

C. Alleged infringement of any patent rights which may be brought arising out of Contractor's work;

D. Claims and liens for labor performed or materials used or furnished to be used on the job, including all incidental or consequential damages from such claims or liens;

E. Contractor's failure to fulfill any of the covenants set forth in these Contract Documents;

F. Failure of Contractor to comply with the provisions of the Contract Documents relating to insurance; and,

G. Any violation or infraction by Contractor of any law, order, citation, rule, regulation, standard, ordinance, or statute in any way relating to the occupational, health, or safety of employees.

The indemnities set forth in this section shall not be limited by the insurance requirements set forth in these Contract Documents.

Contractor's indemnification of City of Vallejo will not include indemnification for claims which arise as the result of the active negligence of City of Vallejo, or the sole negligence or willful misconduct of City, its agents, servants or independent contractors who are directly responsible to City, or for defects in design furnished by such persons.

7-1.12B INSURANCE
Contractor shall procure and maintain for the duration of the contract insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his agents, representatives, employees, or subcontractors. It shall be a

55 | P a g e

requirement under this Agreement that any available insurance proceeds broader than or in excess of the specified minimum Insurance coverage requirements and/or limits shall be available to the Additional Insured.

Furthermore, the requirements for coverage and limits shall be (1) the minimum coverage and limits specified in this Agreement; or (2) the broader coverage and maximum limits of coverage of any Insurance policy or proceeds available to the named Insured; whichever is greater. No representation is made that the minimum Insurance requirements of this agreement are sufficient to cover the obligations of the Contractor under this agreement.

MINIMUM SCOPE AND LIMIT OF INSURANCE
Coverage shall be at least as broad as:

1. Commercial General Liability (CGL): Insurance Services Office (ISO) Form CG 00 01 covering CGL on an “occurrence” basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $5,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit.

2. Automobile Liability: Insurance Services Office Form CA 0001 covering Code 1 (any auto), with limits no less than $5,000,000 per accident for bodily injury and property damage.

3. Workers’ Compensation insurance as required by the State of California, with Statutory Limits, and Employers’ Liability insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.

4. Installation or Property Installation Floater coverage providing property damage coverage for any building, structure, machinery or equipment damaged, impaired, broken, or destroyed during the performance of the Work, including during transit, installation, and testing at the City of Vallejo’s site.

5. Contractors’ Pollution Legal Liability with limits no less than $1,000,000 per occurrence or claim, and $1,000,000 policy aggregate.

If the contractor maintains broader coverage and/or higher limits than the minimums shown above, the City of Vallejo requires and shall be entitled to the broader coverage and/or the higher limits maintained by the contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City of Vallejo.

SELF-INSURED RETENTIONS
Self-insured retentions must be declared to and approved by the City of Vallejo. The City of Vallejo may require the Contractor to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention. The policy language shall provide, or be endorsed to provide, that the self-insured retention may be satisfied by either the named insured or City of Vallejo.

OTHER INSURANCE PROVISIONS
The insurance policies are to contain, or be endorsed to contain, the following provisions:

1. The City of Vallejo, its officers, officials, employees, agents and volunteers are to be covered as additional insureds on the CGL policy with respect to liability arising out of work or operations performed by or on behalf of the Contractor including materials, parts, or equipment furnished in connection with such work or operations and automobiles owned, leased, hired, or borrowed by or on behalf of the Contractor. General liability coverage can be provided in the form of an endorsement to the Contractor’s insurance (at least as broad as ISO Form CG 20 10, CG 11 85 or both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 20 37 forms if later revisions used).

2. For any claims related to this project, the Contractor’s insurance coverage shall be primary insurance coverage at least as broad as ISO CG 20 01 04 13 as respects the City of Vallejo, its officers, officials, employees, agents and volunteers. Any insurance or self- insurance maintained by the City of Vallejo,

56 | P a g e

its officers, officials, employees, or volunteers shall be excess of the Contractor’s insurance and shall not contribute with it.

3. Each insurance policy required by this clause shall be endorsed to state that coverage shall not be suspended, voided, canceled by either party, reduced in coverage or in limits except after thirty (30) days' prior written notice by certified mail, return receipt requested, has been given to the City of Vallejo.

4. The limits of Insurance required in this agreement may be satisfied by a combination of primary and umbrella or excess Insurance. Any umbrella or excess Insurance shall contain or be endorsed to contain a provision that such coverage shall also apply on a primary and non-contributory basis for the benefit of the City of Vallejo before the City’s own Insurance or self-insurance shall be called upon to protect it as a named insured. Contractor agrees to endorse the City of Vallejo as an Additional Insured on the Umbrella or Excess policy, unless the Certificate of Insurance states the Umbrella or Excess policy provides coverage on a “Follow Form” basis.

5. The City of Vallejo reserves the right to modify these requirements, including limits, based on the nature of the risk, prior experience, insurer, coverage, or other special circumstances.

CLAIMS MADE POLICIES
If any coverage required is written on a claims-made coverage form:

1. The retroactive date must be shown, and this date must be before the execution date of the contract or the beginning of contract work.

2. Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of contract work.

3. If coverage is cancelled or non-renewed, and not replaced with another claims-made policy form with a retroactive date prior to the contract effective, or start of work date, the Contractor must purchase extended reporting period coverage for a minimum of five (5) years after completion of contract work.

4. A copy of the claims reporting requirements must be submitted to the City of Vallejo for review.

5. If the services involve lead-based paint or asbestos identification/remediation, the Contractors Pollution Liability policy shall not contain lead-based paint or asbestos exclusions. If the services involve mold identification/remediation, the Contractors Pollution Liability policy shall not contain a mold exclusion, and the definition of Pollution shall include microbial matter, including mold.

ACCEPTABILITY OF INSURERS
Insurance is to be placed with insurers authorized to conduct business in the state with a current Best rating of no less than A: VII, unless otherwise acceptable to the City of Vallejo.

WAIVER OF SUBROGATION
Contractor hereby agrees to waive rights of subrogation which any insurer of Contractor may acquire from Contractor by virtue of the payment of any loss. Contractor agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation. The Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of the City of Vallejo for all work performed by the Contractor, its employees, agents and subcontractors.

VERIFICATION OF COVERAGE
Contractor shall furnish the City of Vallejo with original Certificates of Insurance including all required amendatory endorsements (or copies of the applicable policy language effecting coverage required by this clause) and a copy of the Declarations and Endorsement Page of the CGL policy listing all policy endorsements to City of Vallejo before work begins. However, failure to obtain the required documents prior to the work beginning shall not waive the Contractor’s obligation to provide them. The City of Vallejo reserves the right to require complete, certified copies of all required insurance policies, including endorsements, required by these specifications, at any time. Failure to exercise this right shall not constitute a waiver of

57 | P a g e

right to exercise later. All verification of coverage and other insurance documents shall be mailed to the following address:

City of Vallejo
Attn: Risk Manager
555 Santa Clara Street
Vallejo, CA 94590

SUBCONTRACTORS
Contractor shall require and verify that all subcontractors maintain insurance meeting all requirements stated herein, and Contractor shall ensure that City of Vallejo is an additional insured on insurance required from subcontractors. For CGL coverage, subcontractors shall provide coverage with a form at least as broad as CG 20 38 04 13.

PAYMENT WITHHOLD
City of Vallejo will withhold payments to Contractor if the certificates of insurance and endorsements required in this exhibit are canceled or Contractor otherwise ceases to be insured as required herein. 7-1.12B(4) ENFORCEMENT

The City of Vallejo may take any steps as are necessary to assure Contractor's compliance with its obligations.

Should any insurance policy lapse or be canceled during the Contract period the Contractor shall, within thirty (30) days prior to the effectiv e expiration or cancellation date, furnish the City of Vallejo with evidence of renewal or replacement of the policy. Failure to continuously maintain insurance coverage as herein provided is a material breach of Contract. In the event the Contractor fails to maintain any insurance coverage required, the City of Vallejo may, but is not required to, maintain this coverage and charge the expense to the Contractor or terminate Contractor’s control over the work. The required insurance shall be subject to th e review and acceptance of City of Vallejo, but any acceptance of insurance certificates by the City of Vallejo shall in no way limit or relieve the Contractor of the Contractor's duties and responsibilities under the Contract to indemnify, defend and hold harmless the City of Vallejo, its officers, agents, and employees. Insurance coverage in the minimum amounts set forth herein shall not be construed to relieve the Contractor for liability in excess of such coverage, nor shall it preclude the City of Vallejo from taking other actions as is available to it under any other provision of the Contract or law. Failure of the City of Vallejo to enforce in a timely manner any of the provisions of this section shall not act as a waiver to enforcement of any of these provisions at a later date. 7-1.12B(5) SELF-INSURANCE

Self-insurance programs and self-insured retentions in insurance policies are subject to separate annual review and acceptance by the City of Vallejo of evidence of the Contractor's financial capacity to respond. Additionally, self-insurance programs or r etentions must provide the City of Vallejo with at least the same protection from liability and defense of suits as would be afforded by first-dollar insurance. 7-1.12B(6) MISCELLANEOUS

Nothing contained in the Contract is intended to make the public or any member thereof a third party beneficiary of the Insurance or Indemnity provisions of these Standard Specifications, nor is any term, condition or other provision of the Contract intended to establish a standard of care owed to the public or any member thereof.

7-1.125 LEGAL ACTIONS AGAINST THE CITY OF VALLEJO

In the event litigation is brought against the City of Vallejo concerning compliance by the City of Vallejo with State or federal laws, rules or regulations applicable to public works construction, the provisions of this Section 7-1.125 shall apply.

58 | P a g e

A. If, pursuant to court order, the City of Vallejo prohibits the Contractor from performing all or any portion of the work, the delay will be considered a right of way delay within the meaning of Section 8 -1.09, "Right of Way Delays," unless the Contract is terminated as hereinafter provided.

B. If, pursuant to court order (other than an order to show cause) the City of Vallejo is prohibited from requiring the Contractor to perform all or any portion of the work, the City of Vallejo may, if it so elects, eliminate the enjoined work pursuant to Section 4-1.03, "Changes," or terminate the Contract.

C. If the final judgment in the action prohibits the City of Vallejo from requiring the Contractor to perform all or any portion of the work, the City of Vallejo will either eliminate the enjoined work pursuant to Section 4-1.03, "Changes," or terminate the Contract.

D. If the Contract is to be terminated, the termination and the determination of the total compensation payable to the Contractor shall be governed by the provisions in Section 8 -1.11, "Termination of Contract."
7-1.13 DISPOSAL OF MATERIAL OUTSIDE THE PUBLIC RIGHT OF WAY

If the Contractor elects to dispose of materials at locations other than those where arrangements have been made by the City of Vallejo, or, if material is to be disposed of and the City of Vallejo has not made arrangements for disposal of the material, th e Contractor shall make arrangements for disposing of the materials outside the public right of way and shall pay all costs involved. Arrangements shall include, but not be limited to, entering into agreements with property owners and obtaining necessary permits, licenses and environmental clearances. Before disposing of any material outside the public right of way, the Contractor shall furnish to the Engineer satisfactory evidence that the Contractor has entered into agreements with the property owners of the site(s) involved and has obtained the appropriate permits, licenses and clearances.

When any material is to be disposed of outside the public right of way, and the City of Vallejo has not made arrangements for disposal of the material, the Contractor shall first obtain written authorization from the property owner on whose property the di sposal is to be made and the Contractor shall file with the Engineer the authorization or a certified copy thereof together with a written release from the property owner absolving the City of Vallejo from any and all responsibility in connection with the disposal of material on the property.

Before any material is disposed of on the property, the Contractor shall obtain written permission from the Engineer to dispose of the material at the location designated in the authorization.

When material is disposed of as above provided and the disposal location is visible from public view, the Contractor shall dispose of the material in a neat and uniform manner to the satisfaction of the Engineer.

Where the City of Vallejo has made arrangements with owners of land in the vicinity of a project for the disposal of materials on an owner's property, the arrangements are made solely for the purpose of providing all Bidders an equal opportunity to dispose of the materials on the property. Bidders or Contractors may, upon written request, inspect the documents evidencing the arrangements between property owners and the City of Vallejo.

The Contractor may, if the Contractor so elects, exercise any rights t hat have been obtained, which may be exercised by a Contractor under the arrangements, subject to and upon the conditions hereinafter set forth.

Such arrangements are not a part of the Contract and it is expressly understood and agreed that the City of Vallejo assumes no responsibility to the Bidder or Contractor whatsoever in respect to the arrangements made with the property owner to dispose of materials thereon and that the Contractor shall assume all risks in connection with the use of the property, the terms upon which the use shall be made, and there is no warranty or guaranty, either express or implied, as to the quantity or types of materials that can be disposed of on the property, or that any material can be disposed of on the property.

In those instances in which the City of Vallejo has compiled "Materials Information" as referred to in Section 2-1.03, "Examination of Plans, Specifications, Contract, and Site of Work," the compilation will include the documents setting forth the arrangement made with some of the property owners for the disposal of material

59 | P a g e

on those owners' properties. The inclusion of the documents therein shall not in any respect operate as a waiver of any of the provisions in this Section 7-1.13 concerning the documents.

The Bidder or Contractor shall make such independent investigation and examination as the Bidder or Contractor deems necessary to be satisfied as to the quantity and types of materials which may be disposed of on the property (if any) and the rights, duties and obligations acquired or undertaken under the arrangement with the property owner.

Notwithstanding that the Contractor may elect to dispose of materials on any such property owner's property, no material may be disposed of on that property unless the Contractor has first either:

A. Executed a document that will guarantee to hold the owner harmless from all claims for injury to persons or damage to property resulting from the Contractor's operations on the property owner's premises and also agree to conform to all other provisions set forth in the arrangement made between the City of Vallejo and the property owner, or

B. Entered into an agreement with the owner of the disposal site on any terms mutually agreeable to the owner and the Contractor; provided that the Contractor shall furnish to the Engineer a release, in a form satisfactory to the Engineer, executed by the own er, relieving the City of Vallejo of any and all obligations under the City of Vallejo's arrangement with the owner.

If the Contractor elects to dispose of material under (1), the use of the site shall be subject to the terms, conditions and limitations of the arrangement made between the property owner and the City of Vallejo and the Contractor shall pay those charges t hat are provided for in the arrangement made by the City of Vallejo with the property owner, and deductions will be made from any moneys due or that may become due the Contractor under the Contract sufficient to cover the charges for the material disposed of.

If the Contractor elects to dispose of material under (2), the Contractor shall pay those charges that are provided for in the agreement between the owner and the Contractor and deductions will not be made from any moneys due or that may become due the Contractor under the Contract to cover the charges.

Before acceptance of the Contract, the Engineer may require the Contractor to submit written evidence that the owner of the disposal site is satisfied that the Contractor has satisfactorily complied with the provisions of either - (1), the arrangement betw een the City of Vallejo and the owner, or (2), the agreement between the owner and the Contractor, as the case may be.

Full compensation for all costs involved in disposing of materials as specified in this Section 7 -1.13, including all costs of hauling, shall be considered as included in the price paid for the Contract item of work involving the materials and no additional compensation will be allowed therefor. 7-1.14 COOPERATION
Should construction be under way by other forces or by other Contractors within or adjacent to the limits of the work specified or should work of any other nature be under way by other forces within or adjacent to those limits, the Contractor shall cooperate with all the other Contractors or other forces to the end that any delay or hindrance to their work will be avoided. The City reserves the right to perform, or to have performed, other or additional work at or near the site (including material sources) at any time, by the use of other forces, without changing the character of the work.

When 2 or more Contractors are employed on related or adjacent work, or obtain materials from the same material source, as provided in Section 6 -2.02, "Possible Local Material Sources," or Section 6 -2.03, "Mandatory Local Material Sources," each shall conduct their operations in such a manner as not to cause any unnecessary delay or hindrance to the other.

Each Contractor shall be responsible to the other for all damage to work, to persons or property caused to the other by their operations, and for loss caused the other due to unnecessary delays or failure to finish the work within the time specified for completion.

60 | P a g e

7-1.15 RELIEF FROM MAINTENANCE AND RESPONSIBILITY

Upon request of the Contractor, the Director, or the Director’s designated representative, may relieve the Contractor of the duty of maintaining and protecting certain portions of the work as described below, which have been completed in all respects in accordance with the requirements of the Contract and to the satisfaction of the Engineer, and thereafter except with the Contractor's consent, the Contractor will not be required to do further work thereon. In addition, the action by the Director will relieve the Contractor of responsibility for injury or damage to those completed portions of the work resulting from use by public traffic or from the action of the elements or from any other cause but not from injury or damage resulting from the Contractor's own operations or from the Contractor's negligence.

However, nothing in this Section 7 -1.15 providing for relief from maintenance and responsibility will be construed as relieving the Contractor of full responsibility for making good any defective work or materials found at any time before the formal writte n acceptance of the entire Contract by the Director. Furthermore, nothing in this section shall obligate the Director to relieve the Contractor for responsibility for any portion of the work and the Director may refuse to relieve the Contractor from respo nsibility for any reason, at the Director’s (or his delegee’s) sole discretion.
7-1.16 CONTRACTOR'S RESPONSIBILITY FOR THE WORK AND MATERIALS

The Contractor shall be completely responsible for the care and condition of the project improvements in their entirety until completion of the maintenance period and acceptance by the City. The Contractor shall provide all watchmen, guards, and security devices, as he/she deems necessary.

Until the acceptance of the Contract, the Contractor shall have the charge and care of the work and of the materials to be used therein (including materials for which the Contractor has received partial payment as provided in Section 9-1.06, "Partial Payments," or materials which have been furnished by the City of Vallejo) and shall bear the risk of injury, loss or damage to any part thereof by the action of the elements or from any other cause, whether arising from the execution or from the non -execution of the work, except as provided in Sections 7 -1.08, "Public Convenience," and 7 -1.15, "Relief From Maintenance and Responsibility." The Contractor shall rebuild, repair, restore, and make good all injuries, losses or damages to any portion of th e work or the materials occasioned by any cause before its completion and acceptance and shall bear the expense thereof, except as otherwise expressly provided in Section 7 -1.165, "Damage by Storm, Flood, Tsunami or Earthquake," and in Section 19 -2.04, "Slides and Slipouts," and except for those injuries, losses, or damages that are directly and proximately caused by acts of the Federal Government or the public enemy.

Where necessary to protect the work or materials from damage, the Contractor sha ll, at the Contractor's expense, provide suitable drainage of the roadway and erect those temporary structures that are necessary to protect the work or materials from damage. The suspension of the work from any cause whatever shall not relieve the Contra ctor of the responsibility for the work and materials as herein specified. If ordered by the Engineer, the Contractor shall, at the Contractor's expense, properly store materials which have been partially paid for by the City of Vallejo or which have been furnished by the City of Vallejo. Storage by the Contractor shall be on behalf of the City of Vallejo and the City of Vallejo shall at all times be entitled to the possession of the materials, and the Contractor shall promptly return the materials to the site of the work when requested.

The Contractor shall not dispose of any of the materials so stored except on written authorization from the Engineer.

7-1.165 DAMAGE BY STORM, FLOOD, TSUNAMI OR EARTHQUAKE

Attention is directed to Section 7 -1.16, "Contractor's Responsibility for the Work and Materials." In the event damage to the work is caused by a storm, flood, tsunami, earthquake or other natural disaster which constitutes an "Occurrence," as hereinafter defined, the provisions in this Section 7 -1.165 shall be applicable, and the Contractor may apply in writing to the Engineer for the City of Vallejo to pay or participate in the cost of repairing damage to the work from that cause or, in lieu thereof, and at the sole discretion of the City of Vallejo, terminate the Contract and relieve the Contractor of further obligation to perform the work, subject to the following:

61 | P a g e

A. Occurrence - "Occurrence" shall include tsunamis, earthquakes in excess of a magnitude of 3.5 on the Richter Scale, and storms, floods and other natural disasters as to which the Governor has proclaimed a state of emergency when the damaged work is located within the territorial limits to which the proclamation is applicable or, which were, in the opinion of the Engineer, of a magnitude at the site of the work sufficient to have caused such a proclamation had they occurred in a populated area or in an area in which such a proclamation was not already in effect.

B. Application by Contractor - The Contractor's written request for the City of Vallejo to pay or to participate in the cost of rebuilding, repairing, restoring or otherwise remedying the damage to the work caused by the Occurrence shall be submitted to the Engineer before performing an y work other than emergency work, including emergency work necessary to provide for passage of public traffic.

C. Protecting the Work from Damage - Nothing in this section shall be construed to relieve the Contractor of the responsibility to protect the work from damage. The Contractor shall bear the entire cost of repairing damage to the work caused by the Occurrenc e which the Engineer determines was due to the failure of the Contractor to comply with the requirements of the Contract Documents, take the best measures to protect the work or exercise the best engineering and construction practices in the conduct of the work, and those repair costs shall be excluded from consideration under the provisions of this section.

D. Repair Work - Repair of damaged work under the provisions of this section shall be pursuant to a Contract Change Order issued hereunder and specifying the repair work to be performed on the damaged facility. The repair work shall consist of restoring the in-place construction (for the purposes of this section erected falsework and formwork shall be considered in-place construction) to the same state of completion to which the work had advanced prior to the Occurrence. Emergency work which the Engineer determines would have been part of the repair work if it had not previously been performed, will be considered to be part of the repair work.

The City of Vallejo reserves the right to make changes in the drawings and Specifications applicable to the portions of the work to be repaired, and if those changes will increase the cost of repairing the damage over the Engineer's estimate of the cost of repair without the changes, the Contractor will be paid for the increased costs in accordance with Subsection E and the increased cost amount shall not be considered in determining the cost of repair to be borne by the Contractor under Subsection F.

Nothing in this section shall be construed to relieve the Contractor of full responsibility for the risk of injury, loss or damage to materials not yet incorporated in the work and to materials, tools and equipment (except erected falsework and formwork) used to perform the work, or to relieve the Contractor of responsibility under Section 7-1.12, "Indemnification and Insurance." The provisions of this section shall not be applicable to the repair of damage caused by an Occurrence to any portion of the wor k as to which the Contractor has been granted relief from maintenance and responsibility pursuant to Section 7 -1.15, "Relief From Maintenance and Responsibility," or to the removal of slides and slipouts or the repair and restoration of damage to the work resulting from slides and slipouts pursuant to Section 19-2.04, "Slides and Slipouts."

E. Determination of Costs - Unless otherwise agreed between the Engineer and the Contractor, the cost of the work performed pursuant to this Section 7 -1.165 will be determined in conformance with the provisions in Section 9 -1.03, "Force Account Payment," exc ept there shall be no markup allowance pursuant to Section 9-1.03A, "Work Performed by Contractor," unless the Occurrence that caused the damage was a tsunami or earthquake. The cost of emergency work, which the Engineer determines would have been part of the repair work if it had not previously been performed, will be determined in the same manner as the authorized repair work. The cost o f repairing damaged work which was not in compliance with the requirements of the drawings and Specifications shall be borne solely by the Contractor, and those costs shall not be considered in determining the cost of repair under this Subsection E.

F. Payment for Repair Work - BLANK

62 | P a g e

G. Termination of Contract - If the City of Vallejo elects to terminate the Contract, the termination and the determination of the total compensation payable to the Contractor shall be governed by the provisions of Section 8-1.11, "Termination of Contract."
7-1.17 ACCEPTANCE OF CONTRACT

When the Engineer has made the final inspection as provided in Section 5 -1.13, "Final Inspection," and determines that the Contract work has been completed in all respects in accordance with the Contract Documents, the Engineer will recommend that the Director formally accept the Work as complete. Upon satisfactory completion of the Work and following the written acceptance of the Work as such by the Director or the Director’s designated representative, the Engineer shall recommend the acceptance of the Contract to the City Council. Upon acceptance of the Contract as complete by the City Council, the said Council shall cause a Notice of Completion to be filed and recorded in the records of the Solano County Recorder's Office. 7-1.18 PROPERTY RIGHTS IN MATERIALS

Nothing in the Contract shall be construed as vesting in the Contractor any right of property in the materials used after they have been attached or affixed to the work or soil or after partial payment has been made as provided in Section 9 -1.06, "Partial Payments," for material delivered on the ground or stored subject to or under the control of the City of Vallejo and unused. All the material shall become the property of the City of Vallejo upon being so attached or affixed or upon payment for materials delivered on the ground or stored subject to or under the control of the City of Vallejo and unused, as provided in Section 9 -1.06. 7-1.19 RIGHTS IN LAND AND IMPROVEMENTS

Nothing in these Contract Documents shall be construed as allowing the Contractor to make any arrangements with any person to permit occupancy or use of any land, structure, or building within the limits of the Contract for any purpose whatsoever, either with or without compensation, in conflict with any agreement between the City of Vallejo and any owner, former owner, or tenant of the land, structure, or building.

The Contractor shall not occupy City of Vallejo -owned property outside the right of way as shown on the drawings or maps, unless the Contractor enters into a rental agreement with the City of Vallejo. The agreement will be based on fair rental values.
7-1.20 PERSONAL LIABILITY

Neither the Director, the Engineer nor any other officer or authorized employee of the City of Vallejo, nor any officer or employee of any county, city or district shall be personally responsible for any liability arising under or by virtue of the Contract.
7-1.21 REPAIR OF EQUIPMENT

The work of installing, assembling, repairing or reconditioning, or other work of any nature on machinery, equipment or tools used in or upon the work shall be considered a part of the work to be performed under the Contract and any laborers, workers or mechanics working on the machinery, equipment or tools, unless employed by bona fide commercial repair shops, garages, blacksmith shops or machine shops, which have been established and operating on a commercial basis for a period of at least 2 months prior to the award of the Contract, shall be subject to all the requirements relating to labor set forth in these Contract Documents. 7-1.22 NOT USED

63 | P a g e

END OF SECTION 7

64 | P a g e

SECTION 8: PROSECUTION AND PROGRESS

8-1.01 SUBCONTRACTING

The Contractor shall give personal attention to the fulfillment of the Contract and shall keep the work under the Contractor's control.

No subcontractor will be recognized as such, and all persons engaged in the work of construction will be considered as employees of the Contractor and the Contractor will be held responsible for their work, which shall be subject to the provisions of the Contract Documents.

The Contractor shall perform, with the Contractor's own organization, Contract work amounting to not less than 50 percent of the original total Contract price, except that any designated "Specialty Items" may be performed by subcontract and the amount of a ny designated "Specialty Items" performed by subcontract may be deducted from the original total Contract price before computing the amount of work required to be performed by the Contractor with the Contractor's own organization. When items of work in the Engineer's Estimate are preceded by the letters (S) or (S-F), those items are designated as "Specialty Items." Where an entire item is subcontracted, the value of work subcontracted will be based on the Contract item bid price. When a portion of an item is subcontracted, the value of work subcontracted will be based on the estimated percentage of the Contract item bid price, determined from information submitted by the Contractor, subject to acceptance by the Engineer.

Subcontracts shall include provisions that the Contract between the City of Vallejo and the Contractor is part of the subcontract, and that all terms and provisions of the Contract are incorporated in the subcontract.

Subcontracts shall also contain certi fication by the subcontractor that the subcontractor is experienced in and qualified to do, and knowledgeable about, the subcontracted work. Copies of subcontracts shall be available to the Engineer upon written request, and shall be provided to the Engin eer within three (3) days of the Engineer’s request.

Pursuant to the provisions of Section 6109 of the Public Contract Code, the Contractor shall not perform work on a public works project with a subcontractor who is ineligible to perform work on the public works project pursuant to Section 1777.1 or 1777.7 of the Labor Code.

When a portion of the work which has been subcontracted by the Contractor is not being prosecuted in a manner satisfactory to the City of Vallejo, the subcontractor shall be removed immediately on the request of the Engineer and shall not again be employed on the work.

The roadside production of materials produced by other than the Contractor's forces shall be considered as subcontracted. Roadside production of materials shall be construed to be production of aggregates of all kinds with portable, semi portable or tempo rary crushing or screening, proportioning and mixing plants established or reopened for the purpose of supplying aggregate or material for a particular project or projects. The erection, establishment or reopening of the plants and the operation thereof in the production of materials for use on the work shall conform to the requirements relating to labor set forth in these Specifications and in the special provisions.

When any portion of the work which has been subcontracted by the Contractor is not being prosecuted in a satisfactory manner, the subcontract for such work shall be terminated immediately by the Contractor upon written notice from the Engineer, and the sub contractor shall not again be employed on the type of work in which his or her performance was unsatisfactory.

In no case shall the use of subcontractors in any way alter the position of the Contractor or Contractor's sureties with relation to this Contract. When a subcontractor is used, the responsibility for every portion of the work shall still remain with the Contractor.

65 | P a g e

The Contractor shall pay, when due, all valid claims of subcontractors, suppliers, and workmen with respect to the project.

The mention herein of any specific duty or responsibility imposed upon the Contractor shall not be construed as a limitation or restriction of any other responsibility or duty imposed upon the Contractor by the Contract, said reference being made herein merely for the purpose of explaining the specific duty or responsibility. 8-1.02 ASSIGNMENT

The performance of the Contract may not be assigned, except upon the written consent of the Director.

Consent will not be given to any proposed assignment which would relieve the original Contractor or the Contractor's surety of their responsibilities und er the Contract nor will the Director consent to any assignment of a part of the work under the Contract.

The Contractor may assign moneys due or to become due the Contractor under the Contract and the assignment will be recognized by the City of Vallejo, if given proper notice thereof, to the extent permitted by law, but any assignment of moneys shall be subj ect to all proper set -offs in favor of the City of Vallejo and to all deductions provided for in the Contract and particularly all money withheld, whether assigned or not, shall be subject and subordinate to claims of the City of Vallejo. 8-1.03 BEGINNING OF WORK

The Contractor shall begin work within 10 calendar days after the first working day stated on the Notice to Proceed and shall diligently prosecute the same to completion within the time limit provided in the Notice to Contractors.

The Contractor shall notify the Engineer, in writing, of the Contractor's intent to begin work at least 72 hours before work is begun. The notice shall be delivered to the Engineer and shall specify the date the Contractor intends to start. If the project has more than one location of work, a separate notice shall be given for each location.

Should the Contractor begin work in advance of receiving written Notice to Proceed, any work performed by the Contractor in advance of the date of Notice to Proceed shall be considered as having been done by the Contractor at the Contractor's own risk and as a volunteer.

The Notice to Proceed shall constitute authority for the Contractor to enter upon the site of the work and to begin operations, upon condition that the Contractor has strictly complied with all requirements of these Contract Documents, including but not li mited to, furnishing all required documentation and certificates of insurance. If Contractor has not provided City of Vallejo with all documents required by these Contract Documents as of the date of the Notice to Proceed, Contractor shall not be allowed on the site of the work or allowed to start work on the Project, notwithstanding the issuance of a Notice to Proceed.

When the Contractor has started work on the Project, the Contractor shall diligently prosecute the work to completion within the time limit provided in the Contract Documents.

The counting of working days shall begin on the date stated as the first working day on the Notice to Proceed, whether or not Contractor is allowed on the work site due to Contractor's failure to furnish City of Vallejo with all documentation required by t hese Contract Documents. In no event shall there be a period of time greater than thirty (30) days, from the time the Contract forms are first received by the Contractor and the commencement of the contract time, regardless of the receipt or lack thereof by City of Vallejo of all documents required by these Contract Documents. The Contractor shall, on commencing operations, take all precautions required for public safety and shall observe all the provisions in these Specifications and the special provisions.

66 | P a g e

The Contractor, Architect, City representatives and other interested parties shall meet at a pre-construction conference to be scheduled after execution of the construction Contract and prior to the start of construction. The purpose of this conference is to review including but not limited to job schedules, traffic control, City policies, and to discuss various other aspects of the work and to clarify procedures.

The Contractor shall submit the following to the City Engineer by the date of the pre -construction conference:

A. Detailed CPM Construction Schedule (MS Project or Primavera P6) for review.

B. Traffic Control Plan.

C. All other material or required submittals for review. All submittals shall be in writing.

D. "Notice" to homeowners, residents, commuters and/or affected parties, per section 12-4.01A of the Technical Specifications, for review.
8-1.04 CONSTRUCTION AND MATERIALS

1. Materials and Tests

The Contractor shall furnish written laboratory reports from a reputable testing or inspection agency acceptable to City of Vallejo, or written certification from the manufacturer as to compliance with the Specifications as to the composition, durability and performance of all materials used in the project.

Certain specification sections may require special items or materials to be included in the submittal.

2. City Furnished Materials
The City will furnish to the Contractor free of charge for use under these Specifications the following materials:
(See Technical Specifications)

3. Water

The Contractor can purchase water for use on the project from the City of Vallejo at a cost of $3.53 per unit (100 cu. Ft.) or the most current rate of water used. Water is to be drawn from a Water Division designated fire hydrant after the Contractor has applied to the Water Division for a temporary water meter. A refundable $1,200.00 deposit is required for each temporary water meter at the time of application. There is a non-refundable service charge of $105.00 a month. The Water Division reserves the right to increase the deposit or service charge at any time without notice.

4. Sequence of Construction to Maintain and Control Traffic The Contractor must submit a detailed schedule of operations and a traffic management plan to the Engineer for review and acceptance prior to starting work on the project.

See “Traffic Control” of these Specifications and the project Technical Specifications for compensation.

5. Construction Upon Private Property
The Contractor shall note that the work may be performed on or in the vicinity of private property. The Contractor shall, at all times, remove all litter, debris, and construction waste, minimize noise, dust, standing water, vibrations, hazardous conditio ns and provide safe access to these properties. The Contractor is prohibited from using any privately owned utilities. The Contractor's materials and equipment shall not be stored upon private property without written approval from the resident and/or owner.

Construction on private property during overtime, weekend, holiday, or any other irregular period shall be performed only when the Contractor has requested and received written approval from the adjacent residents and the City Engineer.

67 | P a g e

No separate payment shall be made for the above considerations. Full compensation for the above construction restrictions shall be considered as included in the price paid for the various items of work involved.

6. Watermain Tie-Ins
If a watermain tie -in is required, work shall conform to City Standard Specification Section 4.3.9, "Connecting to Existing main" including, but not limited to the following or as directed by the Engineer:

A. The Contractor is responsible for calling the City Maintenance Division at (707) 648 -4529 when they are ready to perform the tie -in, (Maintenance requires 48 hours’ notice). The Maintenance Inspector shall be present before, during, and after the tie -in is completed, to ensure that the trench is completely back filled before the water is turned on. If the Contractor fails to coordinate the tie-in with the Maintenance Inspector, the said tie-in will not be accepted.

B. If the Contractor schedules a tie-in with the Maintenance Inspector and is not ready for the tie- in on the scheduled date, the contractor will be charged for the Maintenance Inspector's time, unless the Contractor cancels the inspection 24 hours in advance.

7. As-Built Drawings
The Contractor shall always keep an up to date complete and accurate set of record prints, which shall be corrected regularly, showing every change from the Contract Documents, including all addendums, Change Orders, RFIs, etc. Upon completion of the work , a set of as-built prints shall be made by the Contractor after consultation with the Engineer and all changes noted. All changes shall be neatly and legibly drawn to scale on the set of prints using standard architectural or engineering drafting practices.

8. Hazardous Waste in Excavation
If the Contractor encounters material which the contractor has reason to believe may be hazardous waste as defined by Section 25117 of the Health and Safety Code, the contractor shall immediately so notify the Engineer in writing. All work in the immediat e area of the suspected hazardous material shall be suspended until the Engineer authorizes it to be resumed. If such suspension delays the current controlling work by more than one (1) working day, the Contractor shall be granted an extension of time as provided in Section 8-1.07, “Liquidated Damages,” of the General Provisions.

The City reserves the right to use other forces for exploratory work to identify and determine the extent of hazardous material and for removing such material.

9. Changed Conditions
a. Differing Site Conditions
The requirements specified in Section 4-1.06 of the State Standard Specifications for differing site conditions apply to this project.
b. Suspensions of Work Ordered by the Engineer
If the performance of all or any portion of the work is suspended or delayed by the engineer in writing for an unreasonable period of time (not originally anticipated, customary, or inherent to the construction industry) and the contractor believes that additional compensation and/or contract time is due as a result of such suspension or delay, the contractor shall submit to the engineer in writing a request for adjustment within 7 calendar days of receipt of the notice to resume work. The request shall set forth the reasons and support for such adjustment.

Upon receipt, the engineer will evaluate the contractor's request. If the engineer agrees that the cost and/or time required for the performance of the contract has increased as a result of such suspension and the suspension was caused by conditions beyond the control of and not the fault of the contractor, its suppliers, or subcontractors at any approved tier, and not caused by weather, the engineer will make an adjustment (excluding profit) and modify the contract in writing accordingly. The contractor will be notified of the engineer's determination whether an adjustment of the contract is warranted.

68 | P a g e

No contract adjustment will be allowed unless the contractor has submitted the request for adjustment within the time prescribed.

No contract adjustment will be allowed under this clause to the extent that performance would have been suspended or delayed by any other cause, or for which an adjustment is provided or excluded under any other term or condition of this contract.
c. Significant Changes in the Character of Work
The engineer reserves the right to make, in writing, at any time during the work, such changes in quantities and such alterations in the work as are necessary to satisfactorily complete the project. Such changes in quantities and alterations shall not inva lidate the contract nor release the surety, and the contractor agrees to perform the work as altered.

If the alterations or changes in quantities significantly change the character of the work under the contract, whether such alterations or changes are in themselves significant changes to the character of the work or by affecting other work cause such othe r work to become significantly different in character, an adjustment, excluding anticipated profit, will be made to the contract. The basis for the adjustment shall be agreed upon prior to the performance of the work. If a basis cannot be agreed upon, then an adjustment will be made either for or against the contractor in such amount as the engineer may determine to be fair and equitable.

If the alterations or changes in quantities do not significantly change the character of the work to be performed under the contract, the altered work will be paid for as provided elsewhere in the contract.

The term “significant change” shall be construed to apply only to the following circumstances:
• When the character of the work as altered differs materially in kind or nature from that involved or included in the original proposed construction; or
• When a major item of work, as defined elsewhere in the contract, is increased more than 125 percent, or decreased below 75 percent of the original contract quantity. Any allowance for an increase in quantity shall apply only to that portion more than 125 p ercent of the original contract item quantity, or in case of a decrease below 75 percent, to the actual amount of work performed. 8-1.05 TEMPORARY SUSPENSION OF WORK

The Engineer shall have the authority to suspend the work wholly or in part, for any time period as the Engineer deems necessary, due to unsuitable weather, or to such other conditions considered unfavorable for the suitable prosecution of the work, or for any time period as the Engineer deems necessary due to the failure on the part of the Contractor to carry out orders given, or to perform any provision of the Contract, or for any other reason. The Contractor shall immediately comply with the written ord er of the Engineer to suspend the work wholly or in part. The suspended work shall be resumed when conditions are favorable and methods are corrected, as ordered or accepted in writing by the Engineer, or as directed by the Engineer.

In the event that a suspension of work is ordered as provided above, and should that suspension be ordered by reason of the failure of the Contractor to carry out orders or to perform any provision of the Contract; or by reason of weather conditions being unsuitable for performing any item or items of work, which work, in the sole opinion of the Engineer, could have been performed prior to the occurrence of the unsuitable weather conditions had the Contractor diligently prosecuted the work when weather cond itions were suitable; the Contractor, at the Contractor's expense, shall do all the work necessary to provide a safe, smooth, and unobstructed passageway through construction for use by public traffic during the period of that suspension as provided in Sections 7-1.08, "Public Convenience," and 7-1.09, "Public Safety," and as specified in the special provisions for the work. In the event that the Contractor fails to perform the work above specified, the City of Vallejo will perform that work and the cost thereof will be deducted from moneys due or to become due the Contractor.

69 | P a g e

In the event that a suspension of work is ordered by the Engineer due to unsuitable weather conditions, and in the sole opinion of the Engineer, the Contractor has prosecuted the work with energy and diligence prior to the time that operations were suspend ed, the cost of providing a smooth and unobstructed passageway through the work will be paid for as extra work as provided in Section 4-1.03D or, at the option of the Engineer, that work will be performed by the City of Vallejo at no cost to the Contractor.

If the Engineer orders a suspension of all of the work or a portion of the work which is the current controlling operation or operations, due to unsuitable weather or to other conditions considered unfavorable to the suitable prosecution of the work, the d ays on which the suspension is in effect shall not be considered working days as defined in Section 8 -1.06, "Time of Completion." If a portion of work at the time of the suspension is not a current controlling operation or operations, but subsequently doe s become the current controlling operation or operations, the determination of working days will be made on the basis of the current controlling operation or operations.

If a suspension of work is ordered by the Engineer, due to the failure on the part of the Contractor to carry out orders given or to perform any provision of the Contract, the days on which the suspension order is in effect shall be considered working days if those days are working days within the meaning of the definition set forth in Section 8-1.06, "Time of Completion."

No Contract adjustment will be allowed under the provisions specified in this section to the extent that performance would have been suspended or delayed by any other cause, or for which an adjustment is provided for or excluded under any term or condition of this Contract.

Any Contract adjustment warranted due to suspension of work ordered by the Engineer will be made in the same manner as provided for right of way delays in Section 8-1.09, "Right of Way Delays."

In the event of a suspension of work under any of the conditions set forth in this Section 8 -1.05, the suspension of work shall not relieve the Contractor of the responsibilities as set forth in Section 7, "Legal Relations and Responsibility."
8-1.06 TIME OF COMPLETION

The Contractor shall complete all or any designated portion of the work called for under the Contract Documents in all parts and requirements within the time set forth in the Contract Documents.

A working day is defined as any day, except as follows:

A. Saturdays, Sundays and legal holidays;

B. Days on which the Contractor is prevented by inclement weather or conditions resulting immediately therefrom adverse to the current controlling operation or operations, as determined by the Engineer, from proceeding with at least 75 percent of the normal l abor and equipment force engaged on that operation or operations for at least 60 percent of the total daily time being currently spent on the controlling operation or operations; or

C. Days on which the Contractor is prevented, by reason of requirements in "Maintaining Traffic" of the special provisions, from working on the controlling operation or operations for at least 60 percent of the total daily time being currently spent on the controlling operation or operations.

Should the Contractor prepare to begin work at the regular starting time of any day on which inclement weather, or the conditions resulting from the weather, or the condition of the work, prevents the work from beginning at the usual starting time and the crew is dismissed as a result thereof and the Contractor does not proceed with at least 75 percent of the normal labor and equipment force engaged in the current controlling operation or operations for at least 60 percent of the total daily time being currently spent on the

70 | P a g e

controlling operation or operations, the Contractor will not be charged for a working day whether or not conditions should change thereafter during that day and the major portion of the day could be considered to be suitable for those construction operations.

The current controlling operation or operations is to be construed to include any feature of the work (e.g., an operation or activity, or a settlement or curing period) considered at the time by the Engineer and the Contractor, which, if delayed or prolonged, will delay the time of completion of the Contract.

Determination that a day is a non -working day by reason of inclement weather or conditions resulting immediately therefrom, shall be made by the Engineer. The Contractor will be allowed 15 days from the issuance of the weekly statement of working days in which to file a written protest se tting forth in what respects the Contractor differs from the Engineer; otherwise, the decision of the Engineer shall be deemed to have been accepted by the Contractor as correct. The Engineer will furnish the Contractor a weekly statement showing the number of working days charged to the Contract for the preceding week, the number of working days of time extensions being considered or accepted, the number of working days originally specified for the completion of the Contract and the number of working days remaining to complete the Contract and the extended date for completion thereof, except when working days are not being charged in conformance with the provisions in Section 8-1.05, "Temporary Suspension of Work." 8-1.07 LIQUIDATED DAMAGES

It is agreed by the parties to the Contract that in case all the work called for under the Contract in all parts and requirements is not completed within the number of working days as set forth in the Contract Documents, damage will be sustained by the Cit y of Vallejo, and that it is and will be impracticable and extremely difficult to ascertain and determine the actual damage which the City of Vallejo will sustain in the event of and by reason of the delay; and it is therefore agreed that the Contractor wi ll pay to the City of Vallejo, the sum set forth in the Contract Documents per day for each and every calendar day's delay in completing the work in excess of the number of working days prescribed; and the Contractor agrees to pay the liquidated damages he rein provided for, and further agrees that the City of Vallejo may deduct the amount thereof from any moneys due or that may become due the Contractor under the Contract.

The Contractor will be granted an extension of time and will not be assessed with liquidated damages or the cost of engineering and inspection for any portion of the delay in completion of the work beyond the time named in the Contract Documents for the co mpletion of the work caused by acts of God or of the public enemy, fire, floods, tsunamis, earthquakes, epidemics, quarantine restrictions, strikes, labor disputes, shortage of materials and freight embargoes , provided that the Contractor shall notify the Engineer in writing of the causes of delay within 3 days from the beginning of that delay. The Engineer shall ascertain the facts and the extent of the delay, and the Engineer's findings thereon shall be final and conclusive.

No extension of time will be granted for a delay caused by a shortage of materials unless the Contractor furnishes to the Engineer documentary proof that the Contractor has made every effort to obtain the materials from all known sources in a diligent and timely manner, and further proof in the form of supplementary progress schedules, as required in Section 8-1.04, "Progress Schedule," that the inability to obtain the materials when originally planned, did in fact cause a delay in final completion of the entire work which could not be compensated for by revising the sequence of the Contractor's operations. The term "shortage of materials," as used in this section, shall apply only to materials, articles, parts or equipment which are standard items and are to be incorporated in the work. The term "shortage of materials," shall not apply to materials, parts, articles or equipment which are processed, made, constructed, fabricated or manufactured to meet the specific requirements of the Contract. Only the physical shortage of material will be considered under these provisions as a cause for extension of time. Delays in obtaining materials due to priority in filling orders will not constitute a shortage of materials.

Except for the additional compensation provided for in Section 8-1.09, "Right of Way Delays," the Contractor shall have no claim for damage or compensation for any delay or hindrance.

71 | P a g e

It is the intention of the above provisions that the Contractor shall not be relieved of liability for liquidated damages or engineering and inspection charges for any period of delay in completion of the work in excess of that expressly provided for in this Section
8-1.08 TERMINATION OF CONTROL

Whenever, in the opinion of the City of Vallejo, the Contractor has failed to supply an adequate force of labor, equipment, or materials of proper quality, or has failed in any other respect to prosecute the work with the diligence specified in the Contrac t; or if Contractor should refuse or fail to comply with laws, ordinances, or directions of the Engineer; or if Contractor should fail to make prompt payments to subcontractors or for labor or materials; or otherwise be in breach of this Contract; the City of Vallejo may give written notice of at least five (5) calendar days to the Contractor and Contractor's sureties that if the defaults are not remedied within a time specified in such notice, the Contractor's control over the work will be terminated.

If the Contractor should be adjudged a bankrupt, or make an assignment for the benefit of Contractor's creditors, or if a receiver should be appointed on account of Contractor's insolvency, the City of Vallejo may declare the Contractor's control over the work terminated, and so notify the Contractor and Contractor's sureties.

Upon such termination, the City of Vallejo may take possession, and use all or any part, of the Contractor's materials, tools, equipment, and appliances upon the premises to complete the work; the City of Vallejo assuming responsibility for the final relin quishment of such equipment at the conclusion of the work, or sooner, at its option, in as good condition as when it was taken over, reasonable wear and tear excepted; and the City of Vallejo agrees to pay for such materials and the use of said equipment a t a reasonable compensation.

Upon such termination or the City of Vallejo's declaration that the Contractor is in default, the City of Vallejo may direct the surety to complete, or cause to be completed, the Contract work, or the City of Vallejo may direct that all or any part of the work be completed by day labor, or by employment of other contractors on informal contracts, or both. If the City of Vallejo directs the surety to complete or cause to be completed, the Contract work, Contractor's performance bond surety agrees to immedia tely undertake to complete or cause to be completed, all Contract work. If surety fails or refuses to immediately complete or cause to be completed, all Contract work, surety agrees that damage will be sustained by the City of Vallejo, and that it is and will be impracticable to determine the actual amount of damage by reason of such acts; and the Contractor and surety agree that in addition to any other damages City of Vallejo may sustain and may be recovered pursuant to these Contract Documents, including but not limited to, other liquidated damages for delay, or actual damages, the sum of FIVE HUNDRED DOLLARS ($500.00) is a reasonable amount to be charged as liquidated damages for each day surety fails or refuses to complete or cause to be completed, all Contract work, and it is therefore agreed that the Contractor and surety will pay to the City of Vallejo this sum, for each and every calendar day surety fails or refuses to complete or cause to be completed, the Contract work; and the Contractor and s urety further agree that the City of Vallejo may deduct and retain the amount thereof from any monies due the Contractor under the Contract.

If the Contractor's control over the work is terminated as provided above, the Contractor is not entitled to receive any portion of the amount to be paid under the Contract until it is fully completed. After completion, if the unpaid balance exceeds the sum of the amount expended by the City of Vallejo in finishing the work, plus all damages sustained, or to be sustained, by the City of Vallejo, plus any unpaid claims on account of labor, materials, tools, equipment, or supplies contracted for by the Contr actor for the work herein contemplated, the excess not otherwise required by these Contract Documents to be retained shall be paid the Contractor. If the sum so expended exceeds the unpaid balance, the Contractor and Contractor's surety are liable to the City of Vallejo for the amount of such excess. If the surety completes the Contract work as provided above, such surety shall be subrogated to money due under the Contract, and to money which shall become due in the course of completion by the surety. Ho wever, Contractor and surety agree that

72 | P a g e

any subrogation rights of surety are subordinate to and inferior to rights of City of Vallejo.

The City of Vallejo reserves the right to terminate the work for its convenience upon written notice to Contractor. In such event, the Contractor shall be paid its reasonable costs for that portion of the work performed to the date of termination, reasonable costs associated with demobilization, plus fifteen percent (15%) of all such costs for overhead and profit.

8-1.09 RIGHT OF WAY DELAYS

If, through the failure of the City of Vallejo to acquire or clear right of way, the Contractor sustains loss which could not have been avoided by the judicious handling of forces, equipment and plant, there shall be paid to the Contractor that amount that the Engineer may find to be a fair and reasonable compensation for that part of the Contractor's actual loss, that, in the opinion of the Engineer, was unavoidable, determined as follows:

Compensation for idle time of equipment will be determined in the same manner as determinations are made for equipment used in the performance of extra work paid for on a force account basis, as provided in Section 9-1.03A(3), "Equipment Rental," with the following exceptions:

A. The right of way delay factor for each classification of equipment shown in the State Department of Transportation publication entitled Labor Surcharge And Equipment Rental Rates, which is a part of the Contract, will be applied to that equipment rental rate.

B. The time for which the compensation will be paid will be the actual normal working time during which the delay condition exists, but in no case will exceed 8 hours in any one day.

C. The days for which compensation will be paid will be the calendar days, excluding Saturdays, Sundays and legal holidays, during the existence of the delay, except that when rental of equipment is paid for under the provisions in Section 9-1.03A (3b), "Equipment not on the Work," no payment will be made for right of way delays in conformance with the provisions in this Section 8 -1.09.

Actual loss shall be understood to include no items of expense other than idle time of equipment and necessary payments for idle time of workers, cost of extra moving of equipment and cost of longer hauls.

Compensation for idle time of equipment will be d etermined as provided in this Section 8 -1.09 and compensation for idle time of workers will be determined as provided in Section 9 -1.03A(1), "Labor," and no markup will be added in either case for overhead and profit. The cost of extra moving of equipment and the cost of longer hauls will be paid for as extra work as provided in Section 4-1.03D.

If performance of the Contractor's work is delayed as the result of the failure of the City of Vallejo to acquire or clear right of way, an extension of time determined pursuant to the provisions in Section 8 -1.07, "Liquidated Damages," will be granted.
8-1.10 UTILITY AND NON-HIGHWAY FACILITIES

It is anticipated that some or all of the utility and other non-highway facilities, both above ground and below ground, that are required to be rearranged (as used herein, rearrangement includes installation, relocation, alteration or removal) as a part of the highway improvement will be rearranged in advance of constr uction operations. Where it is not anticipated that the rearrangement will be performed prior to construction, or where the rearrangement must be coordinated with the Contractor's construction operations, the existing facilities that are to be rearranged will be indicated on the drawings or in the special provisions. Where a rearrangement is indicated on the drawings or in the special provisions, the Contractor will have no liability for the costs of performing the work involved in the rearrangement. The Contractor shall not be reimbursed for the costs for coordinating with the utility, railroad and non-highway facilities.

73 | P a g e

The right is reserved to the City of Vallejo and the owners of facilities, or their authorized agents, to enter upon the highway right of way for the purpose of making those changes that are necessary for the rearrangement of their facilities or for making necessary connections or repairs to their properties. The Contractor shall cooperate with forces engaged in this work and shall conduct operations in such a manner as to avoid any unnecessary delay or hindrance to the work being performed by the other forces. Wherever necessary, the work of the Contractor shall be coordinated with the rearrangement of utility or other non-highway facilities, and the Contractor shall make arrangements with the owner of those facilities for the coordination of the work.

Attention is directed to the possible existence of underground facilities and utilities not indicated in the Contract Documents and to the possibility that utilities may be in a location different from that which is indicated in the Contract Documents. Th e Contractor shall ascertain the exact location of all utilities , the location of their service laterals or other appurtenances, and of existing service lateral or appurtenances of any other underground facilities prior to doing work.

If the Contractor cannot locate an underground facility or utility whose presence is indicated in the Contract Documents after a diligent search and investigation, the Contractor shall immediately so notify the Engineer in writing. If the facility for which the notice is given is in a substantially different location from that indicated on the drawings or in the special provisions, the additional cost of locating the facility will be paid for as extra work as provided in Section 4-1.03D.

If the Contractor discovers utilities not indicated in the Contract Documents, the Contractor shall immediately give the Engineer and the Utility Company written notification of the existence of those facilities.

The utilities shall be located and protect ed from damage as directed by the Engineer, and the cost of that work will be paid for as extra work as provided in Section 4 -1.03D. The Contractor shall, if directed by the Engineer, repair any damage which may occur to the utilities. The cost of that repair work, not due to the failure of the Contractor to exercise reasonable care or to comply with the terms of the Contract Documents, will be paid for as extra work as provided in Section 4 -1.03D. Damage due to the Contractor's failure to exercise reasonable care or comply with the Contract Documents shall be repaired at the Contractor's cost and expense.

Where it is determined by the Engineer that the rearrangement of an underground facility is essential in order to accommodate the highway improvement and the drawings and Specifications do not provide that the facility is to be rearranged, the Engineer will provide for the rearrangement of the facility by other forces or the rearrangement shall be performed by the Contractor and will be paid for as extra work as provided in Section 4-1.03D.

When ordered by the Engineer in writing, the Contractor shall rearrange any utility or other non -highway facility necessary to be rearranged as a part of the highway improvement, and that work will be paid for as extra work as provided in Section 4-1.03D.

Should the Contractor desire to have any rearrangement made in any utility facility, or other improvement, for the Contractor's convenience in order to facilitate the Contractor's construction operations, which rearrangement is in addition to, or different from, the rearrangements indicated on the drawings or in the special provisions, the Contractor shall make whatever arrangements are necessary with the owners of the utility or other non-highway facility for the rearrangement and bear all expenses in connection therewith.

The Contractor shall immediately notify the Engineer of any delays to the Contractor's operations as a direct result of underground main or trunk line facilities which were not indicated on the drawings or in the special provisions or were located in a position substantially different from that indicated on the drawings or in the special provisions, or as a direct result of utility or other non -highway facilities not being rearranged as herein provided (other than delays in connection with rearrangements made to facilitate the Contractor's construction operations or delays due to a strike or labor dispute). These delays will be considered right of way delays within the meaning of Section 8 -1.09, "Right of Way Delays," and compensation for the delay will be determined in conformance with the provisions in Section 8 -1.09. The Contractor shall be entitled

74 | P a g e

to no other compensation for that delay.

Any delays to the Contractor's operations as a direct result of utility or other non-highway facilities not being rearranged as provided in this Section 8-1.10, due to a strike or labor dispute, will entitle the Contractor to an extension of time as provided in Section 8-1.07, "Liquidated Damages." The Contractor shall be entitled to no other compensation for that delay.
8-1.11 TERMINATION OF CONTRACT

The Contract may be terminated by the Director when termination is authorized by Section 7-1.125, "Legal Actions Against the City of Vallejo," Section 7 -1.165, "Damage by Storm, Flood, Tsunami or Earthquake," or by other provisions of the Contract which authorize termination. The City of Vallejo also reserves the right to terminate the Contract at any time upon a determination by the Director that termination of the Contract is in the best interest of the City of Vallejo.

If the Director elects to terminate the Contract, the termination of the Contract and the total compensation payable to the Contractor shall be governed by the following:

A. The Engineer will issue the Contractor a written notice signed by the Director, specifying that the Contract is to be terminated. Upon receipt of the written notice, the Contractor will be relieved of further responsibility for damage to the work (excludi ng materials) as specified in Section 7 -1.16, "Contractor's Responsibility for the Work and Materials," and, except as otherwise directed in writing by the Engineer, the Contractor shall:

1. Stop all work under the Contract except that specifically directed to be completed prior to acceptance.

2. Perform work the Engineer deems necessary to secure the project for termination.

3. Remove equipment and plant from the site of the work.

4. Take action that is necessary to protect materials from damage.

5. Notify all subcontractors and suppliers that the Contract is being terminated and that their Contracts or orders are not to be further performed unless otherwise authorized in writing by the Engineer.

6. Provide the Engineer with an inventory list of all materials previously produced, purchased or ordered from suppliers for use in the work and not yet used in the work, including its storage location, and such other information as the Engineer may request.

7. Dispose of materials not yet used in the work as directed by the Engineer. It shall be the Contractor's responsibility to provide the City of Vallejo with good title to all materials purchased by the City of Vallejo hereunder, including materials for whic h partial payment has been made as provided in Section 9-1.06, "Partial Payments," and with bills of sale or other documents of title for those materials.

8. Subject to the prior written acceptance of the Engineer, settle all outstanding liabilities and all claims arising out of subcontracts or orders for materials terminated hereunder. To the extent directed by the Engineer, the Contractor shall assign to the City of Vallejo all the right, title and interest of the Contractor under subcontracts or orders for materials terminated hereunder.

9. Furnish the Engineer with the documentation required to be furnished by the Contractor under the provisions of the Contract including, on projects as to which Federal funds are

75 | P a g e

involved, all documentation required under the Federal requirements included in the Contract.

10. Take other actions directed by the Engineer.

B. Acceptance of the Contract as hereinafter specified shall not relieve the Contractor of responsibility for damage to materials. The Contractor shall continue to be responsible for damage to materials after issuance of the Notice of Termination, except as follows:

1. The Contractor's responsibility for damage to materials for which partial payment has been made as provided in Section 9-1.06, "Partial Payments," and for materials furnished by the City of Vallejo for use in the work and unused shall terminate when the Engineer certifies that those materials have been stored in the manner and at the locations the Engineer has directed.

2. The Contractor's responsibility for damage to materials purchased by the City of Vallejo subsequent to the issuance of the notice that the Contract is to be terminated shall terminate when title and delivery of those materials has been taken by the City of Vallejo.

When the Engineer determines that the Contractor has completed the work under the Contract directed to be completed prior to termination and such other work as may have been ordered to secure the project for termination, the Engineer will recommend that the Director formally accept the Contract.

C. Termination of the Contract shall not relieve the Contractor or surety of their obligation for any claims arising out of the work performed.

D. The total compensation to be paid to the Contractor shall be determined by the Engineer on the basis of the following:

1. The reasonable cost to the Contractor, without profit, for all work performed under the Contract, including mobilization, demobilization and work done to secure the project for termination. In determining the reasonable cost, deductions will be made for t he cost of materials to be retained by the Contractor, amounts realized by the sale of materials, and for other appropriate credits against the cost of the work. Deductions will also be made, when the Contract is terminated under the authority of Section 7-1.165, "Damage by Storm, Flood, Tsunami or Earthquake," for the cost of materials damaged by the "occurrence."

When, in the opinion of the Engineer, the cost of a Contract item of work is excessively high due to costs incurred to remedy or replace defective or rejected work, the reasonable cost to be allowed will be the estimated reasonable cost of performing that work in compliance with the requirements of the Contract Documents and the excessive actual cost shall be disallowed.

2. A reasonable allowance for profit on the cost of the work performed as determined under Subsection (1), provided the Contractor establishes to the satisfaction of the Engineer that it is reasonably probable that the Contractor would have made a profit had the Contract been completed and provided further, that the profit allowed shall in no event exceed 4 percent of the cost.

3. The reasonable cost to the Contractor of handling material returned to the vendor, delivered to the City of Vallejo or otherwise disposed of as directed by the Engineer.

4. A reasonable allowance for the Contractor's administrative costs in determining the amount payable due to termination of the Contract.

76 | P a g e

All records of the Contractor and the Contractor's subcontractors, necessary to determine compensation in conformance with the provisions in this Section 8 -1.11, shall be open to inspection or audit by representatives of the City of Vallejo at all times after issuance of the notice that the Contract is to be terminated and for a period of 3 years, thereafter, and those records shall be retained for that perio d.

After acceptance of the work by the Director, the Engineer may make payments on the basis of interim estimates pending issuance of the Final Estimate in conformance with the provisions in Section 9 -1.07B, "Final Payment and Claims," when, in the Engineer's opinion, the amount thus paid, together with all amounts previously paid or allowed, will not result in total compensation in excess of that to which the Contractor will be entitled. All payments, including payment upon the Final Estimate shall be subject to deduction for prior payments and amounts, if any, to be kept or retained under the provisions of the Contract.
8-2.00 SCOPE OF WORK

The Project is located in various streets throughout the City of Vallejo . The work embraced herein will be done in accordance with the Contract Drawings and Specifications, the 2025 Standard Plans and Specifications of the California Department of Transportation, and the City of Vallejo Standard Specifications and Standard Plans dated December 2011.

The work to be done includes furnishing all labor, materials, tax, equipment, incidentals and services for the construction and completion of the 2026 Concrete Improvements Project ( Phase 1 of Cape Seal Project), PROJECT NO. MP-2026 in accordance with the Contract Documents.

For all work on this project the Contractor shall furnish all labor, materials, tools, equipment, transportation, appliances, and services required to completely execute the work as set forth in the Contract Documents

END OF SECTION 8

77 | P a g e

SECTION 9: MEASUREMENT AND PAYMENT

9-1.01 MEASUREMENT OF QUANTITIES (NOT USED)
9-1.015 FINAL PAY ITEMS

When an item of work is designated as (F) or (S -F) in the Engineer's Estimate, the estimated quantity for that item of work shall be the final pay quantity, unless the dimensions of any portion of that item are revised by the Engineer, or the item or any portion of the item is eliminated. If the dimensions of any portion of the item are revised, and the revisions result in an increase or decrease in the estimated quantity of that item of work, the final pay quantity for the item will be revised in the amount represented by the changes in the dimensions, except as otherwise provided for minor structures in Section 5.1 -1.22, "Measurement." If a final pay item is eliminated, the estimated quantity for the item will be eliminated. If a portion of a final pay item is eliminated, the final pay quantity will be revised in the amount represented by the eliminated portion of the item of work.

The estimated quantity for each item of work designated as (F) or (S-F) in the Engineer's Estimate shall be considered as approximate only, and no guarantee is made that the quantity which can be determined by computations, based on the details and dimensions shown on the drawings, will equal the estimated quantity. No allowance will be made in the event that the quantity based on computations does not equal the estimated quantity.

In case of discrepancy between the quantity shown in the Engineer's Estimate for a final pay item and the quantity or summation of quantities for the same item shown on the drawings, payment will be based on the quantity shown in the Engineer's Estimate.

Under no circumstances will Contractor be entitled to payment for any final pay quantity that is greater than the unit quantity price for the final pay quantity item set forth in the proposal form. 9-1.02 SCOPE OF PAYMENT

The Contractor shall accept the compensation provided in the Contract as full payment for furnishing all labor, materials, tools, equipment, and incidentals necessary to the completed work and for performing all work required under the Contract; also for l oss or damage arising from the nature of the work, or from the action of the elements, or from any unforeseen difficulties which may be encountered during the prosecution of the work until the acceptance by the Director and for all risks of every descripti on connected with the prosecution of the work, also for all expenses incurred in consequence of the suspension or discontinuance of the work as provided in the Contract; and for completing the work according to the Contract Documents.

No compensation will be made in any case for loss of anticipated profits. 9-1.03 FORCE ACCOUNT PAYMENT

When extra work is to be paid for on a force account basis, the labor, materials and equipment used in the performance of that work shall be subject to the review and acceptance of the Engineer and compensation will be determined as follows:

78 | P a g e

9-1.03A WORK PERFORMED BY CONTRACTOR

The Contractor will be paid the direct costs for labor, materials and equipment used in performing the work determined as hereinafter provided in Sections 9 -1.03A(1), "Labor," 9 -1.03A(2), "Materials," and 9 -

1.03A(3), "Equipment Rental," except where agreement has been reached to pay in conformance with the provisions in Section 9-1.03B, "Work Performed by Special Forces or Other Special Services."

To the total of the direct costs computed as provided in Sections 9 -1.03A(1), "Labor," 9 -1.03A(2), "Materials," and 9-1.03A(3), "Equipment Rental," there will be added a markup of 33 percent to the cost of labor, 15 percent to the cost of materials and 15 percent to the equipment rental.

The above markups shall constitute full compensation for all overhead costs which shall be deemed to include all items of expense not specifically designated as cost or equipment rental in Sections 9-1.03A(1), "Labor," 9-1.03A(2), "Materials," and 9-1.03A(3), "Equipment Rental." The total payment made as provided above shall be deemed to be the actual cost of the work and shall constitute full compensation therefor.

When extra work to be paid for on a force account basis is performed by a subcontractor, approved in conformance with the provisions in Section 8-1.01, "Subcontracting," an additional markup of 5 percent will be added to the total cost of that extra work including all markups specified in this Section 9 -1.03A. The additional 5 percent markup shall reimburse the Contractor for additional administrative costs, and no other additional payment will be made by reason of performance of the extra work by a subcontractor. 9-1.03A(1) LABOR

The Contractor will be paid the cost of labor for the workers (including foremen when authorized by the Engineer), used in the actual and direct performance of the work. The cost of labor, whether the employer is the Contractor, subcontractor or other forces, will be the sum of the following:
9-1.03A(1a) ACTUAL WAGES

The actual wages paid shall include any employer payments to or on behalf of the workers for health and welfare, pension, vacation, and similar purposes.
9-1.03A(1b) LABOR SURCHARGE

To the actual wages, as defined in Section 9 -1.03A(1a), will be added a labor surcharge set forth in the Caltrans publication entitled Labor Surcharge And Equipment Rental Rates, which is in effect on the date upon which the work is accomplished. The labo r surcharge shall constitute full compensation for all payments imposed by State and Federal laws and for all other payments made to, or on behalf of, the workers, other than actual wages as defined in Section 9 -1.03A(1a) and subsistence and travel allowance as specified in Section 9-1.03A(1C).
9-1.03A(1c) SUBSISTENCE AND TRAVEL ALLOWANCE

The actual subsistence and travel allowance paid to the workers. 9-1.03A(2) MATERIALS

The City of Vallejo reserves the right to furnish any materials it deems advisable, and the Contractor shall have no claims for costs and markup on those materials.

Only materials furnished by the Contractor and necessarily used in the performance of the work will be paid

79 | P a g e

for. The cost of those materials will be the cost to the purchaser, whether Contractor, subcontractor or other forces, from the supplier thereof, except as the following are applicable:
9-1.03A(2A)

If a cash or trade discount by the actual supplier is offered or available to the purchaser, it shall be credited to the City of Vallejo notwithstanding the fact that the discount may not have been taken. 9-1.03A(2B)

If materials are procured by the purchaser by any method which is not a direct purchase from and a direct billing by the actual supplier to the purchaser, the cost of those materials shall be deemed to be the price paid to the actual supplier as determined by the Engineer plus the actual costs, if any, incurred in the handling of the materials.
9-1.03A(2C)

If the materials are obtained from a supply or source owned wholly or in part by the purchaser, the cost of those materials shall not exceed the price paid by the purchaser for similar materials furnished from that source on Contract items or the current w holesale price for those materials delivered to the jobsite, whichever price is lower.
9-1.03A(2D)

If the cost of the materials is, in the opinion of the Engineer, excessive, then the cost of the material shall be deemed to be the lowest current wholesale price at which the materials were available in the quantities concerned delivered to the jobsite, less any discounts as provided in Section 9-1.03A(2a). 9-1.03A(2E)

If the Contractor does not furnish satisfactory evidence of the cost of the materials from the actual supplier thereof within 60 days after the date of delivery of the material or within 15 days after acceptance of the Contract, whichever occurs first, the City of Vallejo reserves the right to establish the cost of the materials at the lowest current wholesale prices at which the materials were available in the quantities concerned delivered to the location of the work, less any discounts as provided in Section 9-1.03A(2a).

80 | P a g e

9-1.03A(3) EQUIPMENT RENTAL

The Contractor will be paid for the use of equipment at the rental rates listed for that equipment in the Caltrans publication entitled Labor Surcharge And Equipment Rental Rates, which is in effect on the date upon which the work is accomplished and which is a part of the Contract, regardless of ownership and any rental or other agreement, if they may exist, for the use of that equipment entered into by the Contractor, except that for those pieces of equipment with a rental rate of $10.00 per hour or less as listed in the Labor Surcharge And Equipment Rental Rates publication and which are rented from a local equipment agency, other than Contractor owned, the Contractor will be paid at the hourly or daily rate shown on the rental agency invoice or agreement for the time used on force account work as provided in Section 9 -1.03A(3a), "Equipment on the Work." If a minimum equipment rental amount is required by the local equipment rental agency, the actual amount charged will be paid to the Contractor.

Equipment owned by the Contractor and already on the job site shall only be paid for actual hours of usage as documented on daily extra work reports. Equipment owned by the Contractor, required to perform force account work, and not already on the job sit e shall only be paid for actual hours of usage as documented on daily extra work reports and the cost of mobilization to bring to the job site. The Engineer shall determine if equipment not on the job site is required to be mobilized to perform extra work.

If it is deemed necessary by the Engineer to use equipment not listed in the Labor Surcharge And Equipment Rental Rates publication, a suitable rental rate for that equipment will be established by the Engineer. The Contractor shall furnish all cost data which might assist the Engineer in the establishment of the rental rate. If the rental rate established by the Engineer is $10.00 per hour or less, the provisions above concerning rental of equipment from a local equipment agency shall apply.

The rental rates paid as above provided shall include the cost of fuel, oil, lubrication, supplies, small tools, necessary attachments, repairs and maintenance of any kind, depreciation, storage, insurance and all incidentals.

Operators of rented equipment will be paid for as provided in Section 9-1.03A(1), "Labor."

All equipment shall, in the opinion of the Engineer, be in good working condition and suitable for the purpose for which the equipment is to be used.

Unless otherwise specified, manufacturer's ratings and manufacturer approved modifications shall be used to classify equipment for the determination of applicable rental rates. Equipment which has no direct power unit shall be powered by a unit of at least the minimum rating recommended by the manufacturer.

Individual pieces of equipment or tools not listed in the Labor Surcharge and Equipment Rental Rate publication and having a replacement value of $500 or less, whether or not consumed by use, shall be considered to be small tools and no payment will be made therefor.

Rental time will not be allowed while equipment is inoperative due to breakdowns. 9-1.03A(3A) EQUIPMENT ON THE WORK

The rental time to be paid for equipment on the work shall be the time the equipment is in operation on the extra work being performed, and in addition, shall include the time required to move the equipment to the location of the extra work and return the equipment to the original location or to another location requiring no more time than that required to return the equipment to its original location, except that moving time will not be paid for if the equipment is used at the site of the extra work on oth er than the extra work. Loading and transporting costs will be allowed, in lieu of moving time, when the equipment is moved by means other than its own power, except that no payment will be made if the equipment is used , at the site of the extra work, on other than the extra work.

81 | P a g e

The following shall be used in computing the rental time of equipment on the work:

A. When hourly rates are listed, less than 30 minutes of operation shall be 0.5-hour of operation.

B. When daily rates are listed, less than 4 hours of operation shall be 0.5-day of operation. 9-1.03A(3B) EQUIPMENT NOT ON THE WORK

When extra work, other than work specifically designated as extra work in the drawings and specifications, is to be paid for on a Force Account basis and the Engineer determines that such extra work requires the Contractor to move on to the work equipment which could not reasonably have been expected to be needed in the performance of the contract, the Engineer may authorize payment for the use of such equipment at equipment rental rates in excess of those listed as applicable for the use of such equipment subject to the following additional conditions:

A. The Engineer shall specifically approve the necessity for the use of equipment on such work.

B. The Contractor shall establish to the satisfaction of the Engineer that such equipment cannot be obtained from his/her normal equipment source or sources and those of his/her subcontractors.

C. The Contractor shall establish to the satisfaction of the Engineer that the proposed equipment rental rate for such equipment from his/her proposed source is reasonable and appropriate for the expected period of use.

D. The Engineer shall approve the equipment source and the equipment rental rate to be paid by the City of Vallejo before the Contractor begins work involving the use of said equipment.

For the use of equipment moved in on the work and used exclusively for extra work paid for on a force account basis, the Contractor will be paid the rental rates listed in the Caltrans publication entitled Labor Surcharge And Equipment Rental Rates, which is in effect on the date upon which the work is accomplished and which is a part of the Contract, or determined as provided in Section 9-1.03A(3) and for the cost of transporting the equipment to the location of the work and its return to its original location, all in accordance with the following provisions:

A. The original location of the equipment to be hauled to the location of the work shall be agreed to by the Engineer in advance.

B. The City of Vallejo will pay the costs of loading and unloading the equipment.

C. The cost of transporting equipment in low bed trailers shall not exceed the hourly rates charged by established haulers.

D. The rental period shall begin at the time the equipment is unloaded at the site of the extra work, shall include each hour that the equipment is actually used at the site of the extra work, excluding Saturdays, Sundays and legal holidays unless the equipment is used to perform the extra work on those days, and shall terminate at the end of the day on which the Engineer directs the Contractor to discontinue the use of the equipment. The rental time to be paid for equipment not on the work shall be the time the equipment is actually in operation on the extra work being performed and in accordance with the following:

The hours to be paid for equipment which is operated less than 8 hours due to breakdowns shall not exceed 8 hours less the number of hours the equipment is inoperative due to breakdowns.

When hourly rates are listed, less than 30 minutes of operation shall be considered to be 0.5 -hour of

82 | P a g e

operation.

When daily rates are listed, less than 4 hours of operation shall be considered to be 4 hours of operation.

No payment will be made if the equipment is not used. If the equipment is used for more than 4 hours of operation, payment will be made for one day.

E. Should the Contractor desire the return of the equipment to a location other than its original location, the City of Vallejo will pay the cost of transportation in accordance with the above provisions, provided the payment shall not exceed the cost of moving the equipment to the work.

F. Payment for transporting, and loading and unloading equipment, as provided above, will not be made if the equipment is used on the work in any other way than upon extra work paid for on a force account basis.
9-1.03A(3C) OWNER-OPERATED EQUIPMENT

When owner-operated equipment is used to perform extra work to be paid for on a force account basis, the Contractor will be paid for the equipment and operator, as follows:

A. Payment for the equipment will be made in conformance with the provisions in Section 9-1.03A(3), "Equipment Rental."

B. Payment for the cost of labor and subsistence or travel allowance will be made at the rates paid by the Contractor to other workers operating similar equipment already on the project or, in the absence of other workers operating similar equipment, at the r ates for that labor established by collective bargaining agreements for the type of workers and location of the work, whether or not the owner-operator is actually covered by an agreement. A labor surcharge will be added to the cost of labor described her ein, in conformance with the provisions in Section 9 -1.03A(lb), "Labor Surcharge."

C. To the direct cost of equipment rental and labor, computed as provided herein, will be added the markups for equipment rental and labor as provided in Section 9-1.03A, "Work Performed by Contractor."
9-1.03A(3D) DUMP TRUCK RENTAL

Dump truck rental shall conform to the provisions in Sections 9-1.03A(3), "Equipment Rental," 9-1.03A(3a), "Equipment on the Work," and 9-1.03A(3b), "Equipment not on the Work," except as follows:

Fully maintained and operated rental dump trucks used in the performance of extra work paid for on a force account basis will be paid for at the same hourly rate paid by the Contractor for use of fully maintained and operated rental dump trucks in performing Contract item work.

In the absence of Contract item work requiring dump truck rental, the Engineer will establish an hourly rental rate to be paid. The Contractor shall provide the Engineer with complete information on the hourly rental rates available for rental of fully maintained and operated dump trucks.

The provisions in Section 9-1.03A(1), "Labor," shall not apply to operators of rented dump trucks.

The rental rates listed for dump trucks in the Caltrans publication entitled Labor Surcharge And Equipment Rental Rates shall not apply.

To the total of the rental costs for fully maintained and operated dump trucks, including labor, there will be added a markup of 15 percent. An additional markup of 5 percent will be added by reason of performance of the work by a subcontractor. No separate markup will be made for labor.

83 | P a g e

The provisions in Section 9-1.03A(3c), "Owner-Operated Equipment," shall not apply to dump truck rentals.

9-1.03B WORK PERFORMED BY SPECIAL FORCES OR OTHER SPECIAL SERVICES

When the Engineer and the Contractor, by agreement, determine that a special service or an item of extra work cannot be performed by the forces of the Contractor or those of any of the Contractor's subcontractors, that service or extra work item may be performed by a specialist. 9-1.03C RECORDS

The Contractor and all subcontractors shall maintain records in such a manner as to provide a clear distinction between the direct costs of extra work paid and the costs of other operations.

From the above records, the Contractor shall furnish the Engineer completed daily extra work reports, either on forms furnished by the City of Vallejo or on computerized facsimiles of the City of Vallejo's forms acceptable to the Engineer, for each day's e xtra work to be paid for on a force account basis. The daily extra work reports shall itemize the materials used and shall state the direct cost of labor and the charges for equipment rental, whether furnished by the Contractor, subcontractor or other forces, except for charges described in Section 9 -1.03B, "Work Performed by Special Forces or Other Special Services." The daily extra work reports shall provide names, identifications, and classifications of all workers, the hourly rate of pay and hours worked, and the size, type and identification number of equipment, and hours operated.

Material charges shall be substantiated by valid copies of vendor's invoices. The invoices shall be submitted with the daily extra work reports, or if not available, the invoices shall be submitted within 30 days after the submittal of the daily extra wor k report or 30 days after the date of delivery of the material, whichever occurs first. Contractor waives payment for material charges not substantiated by valid copies of vendor’s invoices submitted within the times provided.

Daily extra work reports shall be signed by the Contractor or the Contractor's authorized representative and shall be submitted to the City on the day the work is performed, or within 24 hours if authorized by the Engineer. Daily extra work reports shall be signed by the designated representative of the City to acknowledge the labor hours, materials, and equipment used to perform the work. Signature by the City’s representative does not constitute approval for payment. All daily extra work reports are su bject to review and approval by the Engineer for conformance to the Contract Documents prior to payment. The City reserves the right to adjust the amount to be paid for extra work based upon daily extra work reports at any time prior to project acceptance , even if payment has been made under a progress payment. Contractor waives payment for that portion of Force Account work in which a daily extra work report has not been signed by the City’s designated representative and/or submitted to the City within the time specified above.

The Engineer will compare the Engineer's records with the completed daily extra work reports furnished by the Contractor and make any necessary adjustments. When these daily extra work reports are agreed upon and signed by both parties, the reports shall become the basis of payment for the work performed but shall not preclude subsequent adjustment based on a later audit by the City of Vallejo.

The Contractor's and all subcontractors’ records pertaining to the Project shall be open to inspection or audit by representatives of the City of Vallejo, during the life of the Contract and for a period of not less than 3 years after the date of acceptanc e thereof, and the Contractor and all subcontractors shall retain those records for that period. Where payment for materials or labor is based on the cost thereof to forces other than the Contractor, the Contractor shall make every reasonable effort to en sure that the cost records of those other forces will be open to inspection and audit by representatives of the City of Vallejo on the same terms and conditions as the cost records of the Contractor. If an audit is to be commenced more than 60 days after the acceptance date of the Contract, the Contractor will be given a reasonable notice of the time

84 | P a g e

when the audit is to begin.

9-1.03D PAYMENT

Payment as provided in Sections 9-1.03A, "Work Performed by Contractor," and 9-1.03B, "Work Performed by Special Forces or Other Special Services," shall constitute full compensation to the Contractor for performance of work paid for on a force account bas is and no additional compensation will be allowed therefor. The payment will be made in conformance with the provisions in Section 9 -1.06, "Partial Payments."

The Engineer's receipt of a proposed progress schedule and monthly updated progress schedules, all in strict compliance with these Contract Documents shall be conditions precedent to the Engineers acceptance of the Contractor's periodic pay requests and/or the City of Vallejo's obligation to pay Contractor.
9-1.04 (BLANK)
9-1.05 STOP NOTICES

The City of Vallejo may at its option and at any time retain out of any amounts due the Contractor, sums sufficient to cover claims filed pursuant to Section 9356 et seq. of the Civil Code . In cases where the contractor chooses to Bond around the Stop Notice, the Bond shall be of a form approved by the City. 9-1.06 PARTIAL PAYMENTS

The City of Vallejo, once in each month, shall cause an estimate in writing to be made by the Engineer.

The estimate shall include the total amount of work done and acceptable materials furnished, provided the acceptable materials are listed as eligible for partial payment as materials in the special provisions and are furnished and delivered by the Contractor on the ground and not used or are furnished and stored for use on the Contract, if the storage is within the City of Vallejo and the Contractor furnishes evidence satisfactory to the Engineer that the materials are stored subject to or under the control of the City of Vallejo, to the time of the estimate, and the value thereof. The estimate shall also include any amounts payable for mobilization. Daily extra work reports furnished by the Contractor less than 5 calendar days, not including Saturdays, Sundays and legal holidays, prior to the preparation of the monthly progress estimate shall not be eligible for payment until the following month's estimate.

The amount of any material to be considered in making an estimate will in no case exceed the amount thereof which has been reported by the Contractor to the Engineer on City of Vallejo -furnished forms properly filled out and executed, including accompanyin g documentation as therein required, less the amount of the material incorporated in the work to the time of the estimate. Only materials to be incorporated in the work will be considered. The estimated value of the material established by the Engineer will in no case exceed the Contract price for the item of work for which the material is furnished.

Unless otherwise approved by the Engineer in writing, Contractor shall submit to Engineer on or before the tenth (10th) day of the month, an itemized application for payment for the cost of the work in permanent place, which has been completed in strict ac cordance with the Contract Documents as of the last day of the preceding month, less amounts previously paid. The application for payment shall be prepared in a form acceptable to Engineer and shall contain itemized amounts in accordance with the Contract Documents. The applications for payment shall not include requests for payment on account of changes which have not been authorized by Change Orders, or for amounts Contractor does not intend to pay a subcontractor because of a dispute or other reason.

85 | P a g e

If requested by the City of Vallejo, an application for payment shall be accompanied by a summary showing payment that will be made to subcontractors covered by such application, and unconditional waivers and releases of claims and stop notices, from each subcontractor listed in the preceding application for payment covering sums disbursed pursuant to that preceding application for payment.

Contractor warrants that upon submittal of an application for payment, all work has been performed in strict compliance with the Contract Documents, and all work for which certificates of payment have been previously issued and payment has been received from City of Vallejo, shall be free and clear of all claims, stop notices, security interests, and encumbrances in favor of Contractor, subcontractors or other persons or firms entitled to make claims by reason of having provided labor, materials, or equipme nt related to the work.

Payment of all, or any part, of an application for payment may be withheld, a certificate of payment may be withheld, all or part of a previous certificate for payment may be nullified and that amount withheld from a current certificate for payment, or the City of Vallejo may withhold from payment, on account of any of the following:

• Defective work not remedied.

• Third-party claims against Contractor or City of Vallejo arising from the acts or omissions of Contractor or subcontractors.

• Stop notices.

• Failure of Contractor to make timely payments due to subcontractors for material or labor.

• A reasonable doubt that the work can be completed for the balance of the Contract price then unpaid.

• Damage to the City of Vallejo or others for which Contractor is responsible.

• Reasonable evidence that the work cannot be completed within the Contract time, and the unpaid balance of the Contract price would not be adequate to complete the work and cover City of Vallejo's damages for the anticipated delay.

• Failure of Contractor to maintain, update, and submit record documents.

• Failure of Contractor to submit schedules or their updates as required by the Contract Documents.

• Performance of the work by Contractor without properly processed shop drawings.

• Liquidated damages assessed.

• Any other failure of the Contractor to perform its obligations under the Contract Documents.

By resolution of the City of Vallejo’s City Council, a fund has been established, money appropriated in the current budget, and assigned to the account(s) which is/are the sole source(s) of funds available for payment of the Contract price. Contractor und erstands and agrees that Contractor will be paid only from this special fund and if for any reason this fund is not sufficient to pay Contractor, Contractor will not be entitled to payment. The availability of money in this fund, and City of Vallejo's abi lity to draw from this fund, are conditions precedent to City of Vallejo's obligation to make payments to Contractor.

Within thirty (30) days of receipt of an approved certificate for payment, properly executed by the Contractor, City of Vallejo’s Engineer and Director, City of Vallejo agrees to pay Contractor, subject to all of the terms and conditions of these Contract Documents, an amount equal to ninety five percent (95%) of the sum of

86 | P a g e

the following (less any amounts withheld as permitted by the Contract Documents):

Cost of the work in permanent place as of the end of the preceding month as set forth and approved on the certificate for payment; and

Less amounts previously paid.
9-1.065 PAYMENT OF WITHHELD FUNDS

Upon the Contractor's request, the City of Vallejo will make payment of funds withheld from progress payments to ensure performance of the Contract if the Contractor deposits in escrow with the City of Vallejo, or with a bank acceptable to the City of Vallejo, securities equivalent to the amount withheld. The Contractor shall be the beneficial owner of any securities substituted for moneys withheld and shall receive any interest thereon. Upon satisfactory completion of the Contract, the securities shall be returned to the Contractor.

Alternatively, upon the Contractor's request, the City of Vallejo will make payment of retentions earned directly to the escrow agent. The Contractor may direct the investment of the payments into securities, and the Contractor shall receive the interest earned on the investments upon the same terms provided for securities deposited by the Contractor. Upon satisfactory completion of the Contract, the Contractor shall receive from the escrow agent all securities, interest and payments received by the escro w agent from the City of Vallejo.

Alternatively, and subject to the acceptance by the City of Vallejo, the payment of retentions earned may be deposited directly with a person licensed under Division 6 (commencing with Section 17000) of the Financial Code as the escrow agent. Upon written request of an escrow agent that has not been approved by the City of Vallejo under subdivision (c) of Section 10263 of the Public Contract Code, the City of Vallejo will provide written notice to that escrow agent within 10 business days of receipt of the request indicating the reason or reasons for not approving that escrow agent. The payments will be deposited in a trust account with a Federally chartered bank or savings association within 24 hours of receipt by the escrow agent. The Contractor shall n ot place any retentions with the escrow agent in excess of the coverage provided to that escrow agent pursuant to subdivision (b) of Section 17314 of the Financial Code. In all respects not inconsistent with subdivision (c) of Section 10263 of the Public Contract Code, the remaining provisions of Section 10263 of the Public Contract Code shall apply to escrow agents acting pursuant to subdivision (c) of Section 10263 of the Public Contract Code.

Securities eligible for investment shall include those listed in Section 16430 of the Government Code, bank or savings and loan certificates of deposit, interest -bearing demand deposit accounts, standby letters of credit or any other security mutually agreed to by the Contractor and the City of Vallejo.

The escrow agreement used pursuant to this Section 9 -1.065 shall be substantially similar to the "Escrow Agreement for Security Deposits In Lieu of Retention" in Section 10263 of the Public Contract Code, deemed as incorporated herein by reference.

The Contractor shall obtain the written consent of the surety to the agreement. 9-1.07 PAYMENT AFTER ACCEPTANCE

After the work has been accepted in writing by the Director, as provided in Section 7 -1.17, "Acceptance of Contract," payments will be made to the Contractor subject to the provisions in this Section 9 -1.07. 9-1.07A PAYMENT PRIOR TO PROPOSED FINAL ESTIMATE

After acceptance of the work by the Director, the Engineer will make an estimate of the total amount of work done under the Contract and the City of Vallejo will make a final monthly payment pending issuance of the

87 | P a g e

proposed final estimate. The City of Vallejo will pay the balance thereon found to be due after deduction of all previous payments, all amounts to be kept or retained under the provisions of the Contract and those further amounts that the Engineer determi nes to be necessary pending issuance of the proposed final estimate and payment thereon.
9-1.07B FINAL PAYMENT

After written acceptance of the Work as complete by the Director, or the Director’s designated representative, the Engineer will prepare and issue to the Contractor a proposed final estimate in writing of the total amount payable to the Contractor, including therein an itemization of the total amount, segregated as to Contract item quantities, extra work and any other basis for payment, and shall also show therein all deductions made or to be made for prior payments and amounts to be kept or retained under the provisions of the Contract. All prior estimates and payments shall be subject to correction in the proposed final estimate.

The Contractor shall submit written approval of the proposed final estimate or a written statement of all claims arising under or by virtue of the Contract so that the Engineer receives the written approval or statement of claims no later than close of bus iness of the thirtieth day after receiving the proposed final estimate. If the thirtieth day falls on a Saturday, Sunday or legal holiday, then receipt of the written approval or statement of claims by the Engineer shall not be later than close of busines s of the next business day.

No claim will be considered that was not included in the written statement of claims, nor will any claim be allowed as to which a notice or protest is required unless the Contractor has strictly complied with the notice or protest requirements of the Contract Documents.

On the Contractor's approval, or if the Contractor files no claim within the specified period of 30 days, the Engineer will issue a final estimate in writing in accordance with the proposed final estimate submitted to the Contractor. The City of Vallejo w ill pay any remaining moneys unpaid and found to be due in the proposed final estimate 35 days after the recordation of the Notice of Completion in the records of the Solano County Recorder's Office as per Section 7-1.17, "Acceptance of Contract”. That final estimate and payment thereon shall be conclusive and binding against Contractor on all questions relating to the amount of work done and the compensation payable therefor.

If the Contractor within the specified period of 30 days files claims, the Engineer will issue a semifinal estimate in accordance with the proposed final estimate submitted to the Contractor and within 30 days thereafter the City of Vallejo will pay the su m so found to be due. The semifinal estimate and payment thereon shall be conclusive and binding against the Contractor on all questions relating to the amount of work done and the compensation payable therefor, except insofar as affected by the claims filed within the time and in the manner required hereunder.
9-1.07C CLAIMS

The Claims procedures set forth in this section 9 -1.07C are in addition to any claims procedures or rights available to Contractor pursuant to California Public Contract Code section 20104 -20104.6 or California Public Contract Code section 9204 and Contrac tor’s exhaustion of its administrative remedies pursuant to this section 9-1.07C is a condition precedent to Contractor pursuing any claim pursuant to California Public Contract Code section 20104-20104.6 or California Public Contract Code section 9204.

A. General. A “Claim” means a written demand or written assertion by Contractor to adjust, alter, modify, or otherwise change the Contract price or the Contract time, or both. All claims filed hereunder shall strictly comply with all requirements of the Contract Documents.

In order to qualify as a “Claim,” the written demand must state that it is a claim submitted under Section 9 -

1.07C of the Contract Documents. A letter, voucher, invoice, payment application, or other routine or authorized form of request for payment is not a Claim under the Contract Documents. If such a request is disputed as to liability or amount, then the disputed portion of the submission may be converted to a Claim

88 | P a g e

under the Contract Documents by submitting a separate claim in compliance with claim submission requirements.

A Claim must be stated with specificity, including identification of the event or occurrence giving rise to the Claim, the date of the event, and the asserted affect on the Contract price and the Contract time, if any.

The Claim shall include adequate supporting data. Adequate supporting data for a Claim for an adjustment of the Contract time shall include scheduling data demonstrating the impact of the event on the controlling operation and completion of the Project. Adequate supporting data for a Claim for an adjustment in the Contract price shall include a detailed cost breakdown of items included within the Claim and documentation supporting each item of cost.

Notwithstanding and pending the resolution of any Claim, the Contractor shall diligently prosecute the disputed work to final completion of the work. Contractor shall impose the Claim notice and documentation requirements in this Contract on Contractor’s subcontractors of all tiers, and require them to submit to the Contractor all Claims against Contractor and/or City within the times and containing the documentation required by these provisions. The Claim notice and documentation procedure described in these provisions applies to all claims and disputes arising under the Contract Documents, whether or not specifically referred to in any specific portion of the Contract.

If additional information or details are required by the Engineer to determine the basis and amount of any Claims, the Contractor shall furnish additional information or details so that the additional information or details are received by the Engineer no later than the fifteenth day after receipt of the written request from the Engineer. If the fifteenth day falls on a Saturday, Sunday or legal holiday, then receipt of the information or details by the Engineer shall not be later than close of business of the next business day. Contractor understands and agrees that failure to submit the information and details to the Engineer within the time specified shall be result in Contractor waiving that Claim.

The Contractor and all subcontractors shall keep full and complete records of the costs and additional time incurred for any work for which a Claim for additional compensation is made. The Engineer or any designated claim investigator or auditor shall hav e access to those records and any other records as may be required by the Engineer to determine the facts or contentions involved in the claims. Contractor agrees that failure to permit access to those records waives Contractor’s Claims.

The City of Vallejo, or its authorized representatives, shall have access, upon reasonable notice, during normal business hours, to Contractor and subcontractors' books, documents and accounting records, including but not limited to, bid worksheets, bids, subcontractor bids and proposals, estimates, cost accounting data, accounting records, payroll records, time sheets, canceled checks, profit and loss statements, balance sheets, project correspondence including but not limited to all correspondence between Contractor and its sureties and subcontractors/vendors, project files, scheduling information, and other records of the Contractor and all subcontractors directly or indirectly pertinent to the work, original as well as change and claimed extra work, to v erify and evaluate the accuracy of cost and pricing data submitted with any change order, prospective or completed, or any claim for which additional compensation has been requested or claim has been tendered. Such access shall include the right to examine and audit such records, and make excerpts, transcriptions, and photocopies at City of Vallejo's cost.

The parties agree that in the event Contractor or any subcontractor fails to comply with this section, it would be difficult for the City of Vallejo to determine its actual damages; therefore, Contractor agrees to pay City of Vallejo, as liquidated damages, the sum of Two hundred fifty dollars ($250.00), which Contractor agrees is reasonable under the circumstances, for each and every calendar day which Contractor or a subcontractor fails or refuses to provide the City of Vallejo, access to the documents, records and materials specified in this section.

B. Disputes

Contract Interpretation Disputes: Should it appear to the Contractor that the work is to be performed or any of the matters relative to the Contract Documents are not satisfactorily detailed or explained therein, or

89 | P a g e

should any questions arise as to the meaning or intent of the Contract Documents, the Contractor shall give written notice to the City of Vallejo. The Contractor shall bear all costs incurred in the giving of such notice.

All issues regarding the interpretation of the drawings or specifications shall be referred to the City for interpretation. The City shall have the right but not the obligation to affirm or disaffirm any interpretation of the drawings or specifications, w hich affirmance or disaffirmance shall be final. If the Contractor should disagree with the City’s decision, the Contractor’s sole and exclusive remedy is to file a Claim in accordance with these provisions.

Work Disputes: Should any dispute arise under the Contract Documents respecting the true value of any work performed, the implementation of the Work required by the Contract Documents, any Work omitted, any extra work which the Contractor may be required to perform or time extensions, respecting the size of any payment to the Contractor during the performance of the Contract Documents, or of compliance with Contract Documents procedures, the dispute shall be decided by the City of Vallejo and its decision shall be final and conclusive. If the Contractor disagrees with the City’s decision, the Contractor’s sole and exclusive remedy is to file a claim in accordance with these provisions.

C. Delays. As used herein, the following terms shall have the following meanings:

"Excusable Delay" means any delay of the completion of the Project beyond the expiration of the Contract time caused by conditions beyond the control and without the fault or negligence of the Contractor such as strikes, embargoes, fire, unavoidable casualties, unusual delays in transportation, national emergency, and stormy and inclement weather conditions in which the work cannot continue. The financial inability of the Contractor or any subcontractor and default of any subcontractor, without limitation, shall not be deemed conditions beyond the Contractor's control. An Excusable Delay may entitle the Contractor to an adjustment in the Contract time.

"Compensable Delay" means any delay of the completion of the work beyond the expiration date of the Contract time caused by the gross negligence or willful acts of the City of Vallejo, and which delay is unreasonable under the circumstances involved, and n ot within the contemplation of the parties. A Compensable Delay may entitle the Contractor to an extension of the Contract time and/or Contract price.

Except as provided herein, the Contractor shall have no claim for damage or compensation for any delay, interruption, hindrance, or disruption.

"Unexcusable Delay" means any delay of the completion of the Project beyond the expiration of the Contract time resulting from causes other than those listed above. An Unexcusable Delay shall not entitle the Contractor to an extension of the Contract time or an adjustment of the Contract price.

The Contractor may make a Claim for an extension of the Contract time, for an Excusable Delay or a Compensable Delay, subject to the following:

1. If an Excusable Delay and a Compensable Delay occur concurrently, the maximum extension of the Contract time shall be the number of days from the commencement of the first delay to the cessation of the delay which ends last.

2. If an Unexcusable Delay occurs concurrently with either an Excusable Delay or a Compensable Delay, the maximum extension of the Contract time shall be the number of days, if any, by which the Excusable Delay or the Compensable Delay exceeds the Unexcusable Delay.

3. If an Unexcusable Delay occurs concurrently with both an Excusable Delay and a Compensable Delay, the maximum extension in the Contract time shall be the number of days, if any, by which the number of days determined pursuant to Subparagraph (a) exceeds th e number of days of the Unexcusable Delay.

4. For a Compensable Delay, the Contractor shall only be entitled to an adjustment in the Contract Sum in an amount equal to: (1) the actual additional labor costs, material costs, and unavoidable

90 | P a g e

equipment costs incurred by the Contractor as a result of the Compensable Delay, plus the actual additional wages or salaries and fringe benefits and payroll taxes of supervisory and administrative personnel necessary and directly employed at the Project site for the supervision of the work during the period of Compensable Delay; or (2) the Contractor’s Daily Delay Damages set forth in the Bid Form, whichever is less. Except as provided herein, the Contractor shall have no claim for damage or compensation for any delay, interruption, hindrance, or disruption. There shall be no Compensable Delay unless the event or occurrence giving rise to the Compensable Delay extends the actual completion of the Project past the Contract time.

The parties agree that the City of Vallejo's exercise of its right to order changes in the work, regardless of the extent and number of changes, or to suspend the work, is within the contemplation of the parties and shall not be the basis for any Claim for Compensable Delay. The rights of the Contractor to adjustments of the Contract time and the Contract sum, based on changes ordered in the work or suspension of the work, shall be governed by this provision.

Notwithstanding the making of any Claim or the existence of any dispute regarding any Claim, Contractor shall not cause any delay, cessation, or termination in or of Contractor's performance of the work but shall diligently proceed with performance of the work in accordance with the Contract Documents.

Contractor agrees that the daily Contractor Daily Delay Damages as set forth in the Proposal Form shall be full compensation to Contractor, all subcontractors and anyone for whom they may be legally responsible, for each day of delay that may be caused by City of Vallejo or anyone for whom City of Vallejo is legally responsible, including but not limited to, extended field costs, extended home overhead costs, impact, inefficiency, unabsorbed home office overhead, underabsorbed home office overhead, hindran ce, disruption or any other damage arising from delay, no matter how characterized and regardless of the cause, extent or duration of the delay. Inclusion of Contractor Daily Delay Damages within the Proposal Form is solely for the purpose of determining the low Bidder and establishing the City of Vallejo’s maximum daily liability as a result of City of Vallejo delays to Contractor, if any, and City of Vallejo has no obligation to pay any Contractor Daily Delay Damages except as provided for in these Contra ct Documents for Compensable Delays. In the event that City of Vallejo becomes liable to Contractor for compensable delays, City of Vallejo agrees to pay Contractor the Daily Delay Damages set forth in the Proposal Form or Contractor’s actual daily delay damages, whichever is less, for each day of Compensable Delay as provided for by these Contract Documents.

D. Claim Procedures. Should any clarification, determination, action or inaction by the City, Work, or any event, in the opinion of the Contractor, exceed the requirements of or not comply with the Contract Documents, or otherwise result in the Contractor seeking additional compensation in time or money for any reason (collectively “Disputed Work”), then the Contractor and the City shall make good faith attempts to resolve informally any and all such issues and/or disputes. The Contractor must file a written Notice of Poten tial Claim with the City on the form provided in the Contract Documents before commencing the Disputed Work, or within seven (7) calendar days after Contractor’s first knowledge of the Disputed Work, whichever is earlier, stating clearly and in detail its objection and reasons for contending the Work or interpretation is outside the requirements of the Contract Documents. If a written Notice of Potential Claim is not filed within this time period, or if the Contractor proceeds with the Disputed Work withou t first having filed the notice required by these provisions, the Contractor shall waive any rights to further claim on the specific issue.

The City will review the Contractor’s timely Notice of Potential Claim and provide a decision. The City may require supplemental information from the Contractor to clarify that contained in the Notice of Potential Claim. If, after receiving the City’s decision, the Contractor disagrees with the decision, the Contractor shall so notify the City, in writing, within seven (7) calendar days after receiving the decision, that a formal Claim will be filed. The Contractor shall submit the Claim in the form spec ified herein and all arguments, justification, costs or estimates, schedule analyses, and detailed documentation supporting the Contractor’s position within thirty (30) calendar days after receiving the City’s decision on the Notice of Potential Claim.

The Contractor’s failure to furnish notification within seven (7) calendar days and all justifying documentation within thirty (30) calendar days will result in the Contractor waiving all rights to the subject

91 | P a g e

Claim.

If Disputed Work persists longer than thirty (30) calendar days after receiving the City’s decision on the Notice of Potential Claim, then the Contractor shall, every thirty (30) calendar days until the Disputed Work ceases, submit to the City a document t itled “Claim Update” which shall update and quantify all elements of the Claim as completely as possible. The Contractor’s failure to submit a Claim Update or to quantify all costs and impacts every thirty (30) days shall result waiver of that portion of the Claim for that thirty (30) day period. Claims or Claim Updates stating that damages will be determined at a later date shall not comply with the requirements of these provisions and shall result in the Contractor waiving such Claim(s) and/or Claim Updates.

All Claims must be submitted to Engineer before the issuance of the final estimate. Contractor hereby expressly waives all Claims not submitted, in complete and proper form, on or before the date of issuance of the final estimate.

Upon receipt of the Contractor’s formal Claim including all arguments, justifications, costs or estimates, schedule analyses, and documentation supporting the Contractor’s position as previously stipulated, the City or its designate will review the Claim a nd render a final determination. If the Contractor’s Claims at project completion total less than $375,000, then claims resolution shall proceed in the manner prescribed by Article 1.5, Chapter 1, Part 3 of Division 2 of the California Public Contract Cod e.

Claims shall be calculated in the same manner as extra work using the procedures set forth in Section 9 -

1.03 “Force Account Payment.” This method applies in all cases of Claims, regardless of type, whether in negotiation, arbitration, litigation, and even applies in the event of fault, negligence, strict liability, or tort claims of all kinds, including strict liability or negligence. No other costs arising out of or connected to with the performance of Claims, of any nature, may be recovered by the Contractor. Except where provided by law, or elsewhere in these Contract Documents (if applicable), the City shall not be liable for special or consequential damages, and Claims shall not include special or consequential damages. Contractor shall be limited in its recovery on Claims to the calculations set forth in Section 9-1.03 of these provisions.

E. Claim Format. The Contractor shall submit the Claim justification in the following format:

1. Cover letter and certification of the accuracy of the contents of the Claim;

2. Summary of Claim including underlying facts, entitlement, quantum calculations and Contract Document provisions supporting relief;

3. List of documents relating to Claim including drawings, specifications, clarifications/requests for information, schedules and others;

4. Chronology of events and correspondence;

5. Analysis of Claim merit;

6. Analysis of Claim costs;

7. Attached supporting documents referenced in Item 3.) above.

F. Exclusive Remedy. The Contractors performance of its duties and obligations specified in these provisions and submission of a Claim as provided in these provisions is the Contractor’s sole and exclusive remedy for the payment of money, extension of time, adjustment or in terpretation of Contract Documents terms or other contractual or tort relief arising from the Contract Documents.

This exclusive remedy and the limitation of liability (expressed herein and elsewhere throughout the Contract Documents) apply notwithstandin g the completion, termination, suspension, cancellation, breach or rescission of the Work or the Contract Documents, negligence or strict liability by the City of Vallejo, its representatives, consultants or agents, or the transfer of the Work

92 | P a g e

or the Project to the City for any reason whatsoever. The Contractor waives all claims of waiver, estoppel, release, bar, or any other type of excuse for non -compliance with the Claim submission requirements. Compliance with the notice and Claim submissi on procedures described in these provisions is a condition precedent to the right to commence litigation, file a Government Code Claim, or commence any other legal action. No Claim or issues not raised in a timely protest and timely Claim submitted under these provisions may be asserted in any Government Code Claim, subsequent litigation, or legal action. The City of Vallejo shall not have deemed to waive any provision under this Section, if at the City’s sole discretion, a Claim is accepted in a manner n ot in accord with this Section.

G. Mediation. All Claims not subject to the Claim resolution procedures set forth in these provisions shall, as a condition precedent to litigation thereon, first be mediated. Mediation shall be non - binding and utilize the services of a mediator mutually acceptable to the parties, and, if the parties cannot agree, a mediator selected by the American Arbitrator Association from its panel of approved mediators trained in construction industry mediation. All statutes of limitation shall be tolled from the date of the d emand for mediation until a date two weeks following the mediation’s conclusion. All unresolved claims shall be submitted to the same mediator. The cost of mediation shall be equally shared.
9-1.07D False Claims

California Penal Code section 72, provides that any person who presents for payment with intent to defraud any city board or officer, any false or fraudulent claim, bill, account, voucher, or writing, is punishable by fines not exceeding ten thousand dollars ($10,000.00) and/or imprisonment in the state prison.

Government Code sections 12650, et seq., pertains to civil penalties that may be recovered from persons (including corporations, etc.) for presenting a false claim for payment or approval, presents a false record or statement to get a false claim paid or approved, or other acts, to any officer or employee of any political subdivision of the State of California. Any person or corporation violating the provisions of Government Code sections 12650, et seq., shall be liable for three times the amount of the da mages of the political subdivision, plus a civil penalty, plus costs.

All Claims by Contractor shall include the following certification, properly completed and executed by Contractor or an officer of Contractor:

I, __________________, BEING THE _________________ (MUST BE AN OFFICER) OF _____________________ (CONTRACTOR), DECLARE UNDER PENALTY OF PERJURY UNDER THE LAWS OF THE STATE OF CALIFORNIA, AND DO PERSONALLY CERTIFY AND ATTEST THAT: I HAVE

THOROUGHLY REVIEWED THE ATTACHED CLAIM FOR ADDITIONAL COMPENSATION AND/OR EXTENSION OF TIME, AND KNOW ITS CONTENTS, AND SAID CLAIM IS TRUTHFUL AND ACCURATE;

THAT THE AMOUNT REQUESTED ACCURATELY REFLECTS THE CONTRACT ADJUSTMENT FOR WHICH THE OWNER IS LIABLE; AND, FURTHER, TH AT I AM FAMILIAR WITH CALIFORNIA PENAL CODE SECTION 72 AND CALIFORNIA GOVERNMENT CODE SECTION 12650, ET SEQ, PERTAINING

TO FALSE CLAIMS, AND FURTHER KNOW AND UNDERSTAND THAT SUBMISSION OR

CERTIFICATION OF A FALSE CLAIM MAY LEAD TO FINES, IMPRISONMENT AND/O R OTHER SEVERE LEGAL CONSEQUENCES.

Contractor agrees that submission of a Claim, in strict conformance with all of the requirements of this Contract, and rejection of all or part of said Claim by City of Vallejo, is a condition precedent to any action by Contractor against City of Vallejo, including but not limited to, the submission of a claim pursuant to Government Code section 900, et seq., and the filing of a lawsuit.

Any claim for overhead type expenses or costs, in addition to being certified as stated above, shall be supported by an audit report of an independent Certified Public Accountant provided by Contractor with the claim.

93 | P a g e

Contractor agrees that any costs or expenses incurred by the City of Vallejo in reviewing or auditing any claims that are not supported by the Contractor's cost accounting or other records, or the Contract, shall be deemed to be damages incurred by the Cit y of Vallejo within the meaning of the California False Claims Act.

Upon final determination of the claims, the Engineer will then make and issue the Engineer's final estimate in writing and within 30 days thereafter the City of Vallejo will pay the entire sum, if any, found due thereon.

That final estimate shall be concl usive and binding against Contractor on all questions relating to the amount of work done and the compensation payable therefor. 9-1.08 (BLANK)
9-1.09 CLERICAL ERRORS

Notwithstanding the provisions in Section 9-1.07, "Payment After Acceptance," for a period of 3 years after acceptance of the work, all estimates and payments made pursuant to Section 9 -1.07, including the final estimate and payment, shall be subject to co rrection and adjustment for clerical errors in the calculations involved in the determination of quantities and payments. The Contractor and the City of Vallejo agree to pay to the other any sum due under the provisions of this Section 9 -1.09, provided, h owever, if the total sum to be paid is less than $200, no payment shall be made. 9-1.10 (BLANK)
9-1.11 CONTRACTOR NOT AN AGENT OF THE CITY OF VALLEJO

The right of general supervision shall not make the Contractor an agent of the City of Vallejo, and the liability of the Contractor for all damages to persons or to public or private property arising from the performance of the work shall not be lessened because of such general supervision. 9-1.12 THIRD-PARTY CLAIMS

The Contractor shall be responsible for all third -party claims, and for costs or injuries incurred by a third party which result from the operations of the Contractor, or its performance under the Contract. 9-1.13 GUARANTEE

Should any failure of the work occur within a period of one year after recordation of the notice of completion of the project or portions thereof, which can be attributed to faulty materials, poor workmanship, or defective equipment, the Contractor shall promptly make the needed repairs at Contractor's expense.

The City of Vallejo is hereby authorized to make such repairs if the Contractor fails to make or undertake with due diligence the aforesaid repairs within ten (10) days after Contractor is given written notice of such failure and without notice to the surety provided, however, that in case of emergency where, in the opinion of the City of Vallejo, delay would cause serious loss or damages, or a serious hazard to the public, the repairs may be made or lights, signs, and barricades erected, without prior noti ce to the Contractor or surety, and the Contractor shall pay the entire costs thereof. 9-1.14 MISCELLANEOUS PROVISIONS

This Contract shall bind and inure to the heirs, devisees, assignees, and successors in interest of Contractor, and to the successors in interest of City of Vallejo, in the same manner as if such parties had

94 | P a g e

been expressly named herein.

This Contract shall be governed by the laws of the State of California.

If any one or more of the provisions contained in the Contract should be invalid, illegal, or unenforceable in any respect, the validity, legality, and enforceability of the remaining provisions contained herein shall not in any way be affected or impaired thereby.

This Contract constitutes the full and complete understanding of the parties, and supersedes any previous agreements or understandings, oral or written, with respect to the subject matter hereof. The Contract may only be modified by a written instrument signed by both parties.

Contractor hereby assigns to City of Vallejo all its first -tier subcontracts now or hereafter entered into by Contractor for performance of any part of the work. The assignment will be effective upon acceptance by City of Vallejo in writing, and only as to those subcontracts which City of Vallejo designates in writing. Such assignment is part of the consideration to City of Vallejo for entering into the Contract with Contractor, and may not be withdrawn.

The provisions of the Contract Documents shall be included in all subcontracts. 9-1.15 PUBLIC CONTRACT CODE
9-1.15A PUBLIC CONTRACT CODE SECTION 20104, ET SEQ.

Public Contract Code section 20104, et seq., requires that the following language be set forth in the specifications:

§ 20104 - Application of article; provisions included in plans and specifications.

(a) (1) This article applies to all public works claims of three hundred seventy -five thousand dollars ($375,000) or less which arise between a contractor and a local agency.

(2) This article shall not apply to any claims resulting from a contract between a contractor and a public agency when the public agency has elected to resolve any disputes pursuant to Article 7.1 (commencing with Section 10240) of Chapter 1 of Part 2.

(b) (1) “Public work” means “public works contract” as defined in Section 1101 but does not include any work or improvement contracted for by the state or the Regents of the University of California.

(2) “Claim” means a separate demand by the contractor for (A) a time extension, (B) payment of money or damages arising from work done by, or on behalf of, the contractor pursuant to the contract for a public work and payment of which is not otherwise expressly provided for or the claimant is not otherwise entitled to, or (C) an amount the payment of which is disputed by the local agency.

(c) The provisions of this article or a summary thereof shall be set forth in the plans or specifications for any work which may give rise to a claim under this article.

(d) This article applies only to contracts entered into on or after January 1, 1991.

§ 20104.2 - Claims; requirements; tort claims excluded.

For any claim subject to this article, the following requirements apply:

(a) The claim shall be in writing and include the documents necessary to substantiate the claim. Claims must be filed on or before the date of final payment. Nothing in this subdivision is intended to extend the

95 | P a g e

time limit or supersede notice requirements otherwise provided by contract for the filing of claims.

(b) (1) For claims of less than fifty thousand dollars ($50,000), the local agency shall respond in writing to any written claim within 45 days of receipt of the claim, or may request, in writing, within 30 days of receipt of the claim, any additional documentation supporting the claim or relating to defenses to the claim the local agency may have against the claimant.

(2) If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement of the local agency and the claimant.

(3) The local agency’s written response to the claim, as further documented, shall be submitted to the claimant within 15 days after receipt of the further documentation or within a period of time no greater than that taken by the claimant in producing the additional information, whichever is greater. (c) (1) For claims of over fifty thousand dollars ($50,000) and less than or equal to three hundred seventy - five thousand dollars ($375,000), the local agency shall respond in writing to all written claims within 60 days of receipt of the claim, or may request, in writing, within 30 days of receipt of the claim, any additional documentation supporting the claim or relating to defenses to the claim the local agency may have against the claimant.

(2) If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement of the local agency and the claimant.

(3) The local agency’s written response to the claim, as further documented, shall be submitted to the claimant within 30 days after receipt of the further documentation, or within a period of time no greater than that taken by the claimant in producing th e additional information or requested documentation, whichever is greater.

(d) If the claimant disputes the local agency’s written response, or the local agency fails to respond within the time prescribed, the claimant may so notify the local agency, in writing, either within 15 days of receipt of the local agency’s response or w ithin 15 days of the local agency’s failure to respond within the time prescribed, respectively, and demand an informal conference to meet and confer for settlement of the issues in dispute. Upon a demand, the local agency shall schedule a meet and confer conference within 30 days for settlement of the dispute.

(e) Following the meet and confer conference, if the claim or any portion remains in dispute, the claimant may file a claim as provided in Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code. For purposes of those provisions, the running of the period of time within which a claim must be filed shall be tolled from the time the claimant submits his or her written claim pursuant to subdivision (a) until the time that c laim is denied as a result of the meet and confer process, including any period of time utilized by the meet and confer process.

(f) This article does not apply to tort claims and nothing in this article is intended nor shall be construed to change the time periods for filing tort claims or actions specified by Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with S ection 910) of Part 3 of Division 3.6 of Title 1 of the Government Code.

§ 20104.4 - Civil action procedures; mediation and arbitration; trial de novo; witnesses

The following procedures are established for all civil actions filed to resolve claims subject to this article:

(a) Within 60 days, but no earlier than 30 days, following the filing or responsive pleadings, the court shall submit the matter to nonbinding mediation unless waived by mutual stipulation of both parties. The mediation process shall provide for the selection within 15 days by both parties of a disinterested third person as mediator, shall be commenced within 30 days of the submittal, and shall be concluded within 15 days from the commencement of the mediation unless a time requirement is extended upon a go od cause showing to the court or by stipulation of both parties. If the parties fail to select a mediator within

96 | P a g e

the 15-day period, any party may petition the court to appoint the mediator.

(b) (1) If the matter remains in dispute, the case shall be submitted to judicial arbitration pursuant to Chapter

2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, notwithstanding Section 1141.11 of that code. The Civil Discovery Act (Title 4 (commencing with Section 2016.010) of Part 4 of the Code of Civil Procedure) shall apply to any proceeding brought under this subdivision consistent with the rules pertaining to judicial arbitration.

(2) Notwithstanding any other provision of law, upon stipulation of the parties, arbitrators appointed for purposes of this article shall be experienced in construction law, and, upon stipulation of the parties, mediators and arbitrators shall be paid nece ssary and reasonable hourly rates of pay not to exceed their customary rate, and such fees and expenses shall be paid equally by the parties, except in the case of arbitration where the arbitrator, for good cause, determines a different division. In no event shall these fees or expenses be paid by state or county funds.

(3) In addition to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, any party who after receiving an arbitration award requests a trial de novo but does not obtain a more favorable judgment shall, in additi on to payment of costs and fees under that chapter, pay the attorney’s fees of the other party arising out of the trial de novo.

(c) The court may, upon request by any party, order any witnesses to participate in the mediation or arbitration process.

§ 20104.6 - Payment on undisputed portion of claim; interest on arbitration awards or judgments

(a) No local agency shall fail to pay money as to any portion of a claim which is undisputed except as otherwise provided in the contract.

(b) In any suit filed under Section 20104.4, the local agency shall pay interest at the legal rate on any arbitration award or judgment. The interest shall begin to accrue on the date the suit is filed in a court of law.
9-1.15B PUBLIC CONTRACT CODE SECTION 9204

Public Contract Code § 9204

Public Contract Code section 9204 requires that the following language be set forth in the specifications:

(a) The Legislature finds and declares that it is in the best interests of the state and its citizens to ensure that all construction business performed on a public works project in the state that is complete and not in dispute is paid in full and in a timely manner.

(b) Notwithstanding any other law, including, but not limited to, Article 7.1 (commencing with Section 10240) of Chapter 1 of Part 2, Chapter 10 (commencing with Section 19100) of Part 2, and Article 1.5 (commencing with Section 20104) of Chapter 1 of Part 3, this section shall apply to any claim by a contractor in connection with a public works project.

(c) For purposes of this section:

(1) “Claim” means a separate demand by a contractor sent by registered mail or certified mail with return receipt requested, for one or more of the following:

(A) A time extension, including, without limitation, for relief from damages or penalties for delay assessed by a public entity under a contract for a public works project.

97 | P a g e

(B) Payment by the public entity of money or damages arising from work done by, or on behalf of, the contractor pursuant to the contract for a public works project and payment for which is not otherwise expressly provided or to which the claimant is not otherwise entitled.

(C) Payment of an amount that is disputed by the public entity.

(2) “Contractor” means any type of contractor within the meaning of Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code who has entered into a direct contract with a public entity for a public works project.

(3) (A) “Public entity” means, without limitation, except as provided in subparagraph (B), a state agency, department, office, division, bureau, board, or commission, the California State University, the University of California, a city, including a charter city, county, including a charter county, city and county, including a charter city and county, district, special district, public authority, political subdivision, public corporation, or nonprofit transit corporation wholly owned by a public agency and formed to carry out the purposes of the public agency.

(B) “Public entity” shall not include the following:

(i) The Department of Water Resources as to any project under the jurisdiction of that department.

(ii) The Department of Transportation as to any project under the jurisdiction of that department.

(iii) The Department of Parks and Recreation as to any project under the jurisdiction of that department.

(iv) The Department of Corrections and Rehabilitation with respect to any project under its jurisdiction pursuant to Chapter 11 (commencing with Section 7000) of Title 7 of Part 3 of the Penal Code.

(v) The Military Department as to any project under the jurisdiction of that department.

(vi) The Department of General Services as to all other projects.

(vii) The High-Speed Rail Authority.

(4) “Public works project” means the erection, construction, alteration, repair, or improvement of any public structure, building, road, or other public improvement of any kind.

(5) “Subcontractor” means any type of contractor within the meaning of Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code who either is in direct contract with a contractor or is a lower tier subcontractor.

(d) (1) (A) Upon receipt of a claim pursuant to this section, the public entity to which the claim applies shall conduct a reasonable review of the claim and, within a period not to exceed 45 days, shall provide the claimant a written statement identifying what portion of the claim is disputed and what portion is undisputed. Upon receipt of a claim, a public entity and a contractor may, by mutual agreement, extend the time period provided in this subdivision.

(B) The claimant shall furnish reasonable documentation to support the claim.

(C) If the public entity needs approval from its governing body to provide the claimant a written statement identifying the disputed portion and the undisputed portion of the claim, and the governing body does not meet within the 45 days or within the mutually agreed to extension of time following receipt of a claim sent by registered mail or certified mail, return receipt requested, the public entity shall have up to three days following the next duly publicly noticed meeting of the governing body after the 45-day period, or extension, expires to provide the claimant a written statement identifying the disputed portion and the undisputed portion.